[Federal Register Volume 59, Number 30 (Monday, February 14, 1994)]
[Unknown Section]
[Page 0]
From the Federal Register Online via the Government Publishing Office [www.gpo.gov]
[FR Doc No: 94-3117]


[[Page Unknown]]

[Federal Register: February 14, 1994]


-----------------------------------------------------------------------

DEPARTMENT OF AGRICULTURE
Farmers Home Administration

7 CFR Parts 1924, 1930, and 1944

RIN 0575-AB08

 

Cost Containment and Vulnerability

AGENCY: Farmers Home Administration, USDA.

ACTION: Final rule.

-----------------------------------------------------------------------

SUMMARY: The Farmers Home Administration (FmHA) amends its regulations 
regarding the processing of preapplications for Rural Rental Housing 
(RRH) assistance. This action is necessary to decrease costs associated 
with the program and to reduce program vulnerability. The intended 
effect is to improve credit quality and to make our regulations more 
responsive to the prudent development of RRH complexes in rural 
America.

EFFECTIVE DATE: March 14, 1994.

FOR FURTHER INFORMATION CONTACT: Gail McCowan, Senior Loan Specialist, 
Rural Rental Housing Branch, Multi-Family Housing Processing Division, 
Farmers Home Administration, USDA, Room 5337--South Agriculture 
Building, Washington, DC 20250, telephone (202) 720-1608.

SUPPLEMENTARY INFORMATION:

Classification

    We are issuing this final rule in conformance with Executive Order 
12866, and we have determined that it is not a ``significant regulatory 
action.'' Based on information compiled by the Department, we have 
determined that this final rule:
    (1) Would have an effect on the economy of less than $100 million;
    (2) Would not adversely affect in a material way the economy, a 
sector of the economy, productivity, competition, jobs, the 
environment, public health or safety, or State, local or tribal 
governments or communities;
    (3) Would not create a serious inconsistency or otherwise interfere 
with an action taken or planned by another agency;
    (4) Would not alter the budgetary impact of entitlements, grants, 
user fees, or loan programs or rights and obligations of recipients 
thereof; and
    (5) Would not raise novel legal or policy issues arising out of 
legal mandates, the President's priorities, or principles set forth in 
Executive Order 12866.

Environmental Impact Statement

    This document has been reviewed in accordance with 7 CFR part 1940, 
Subpart G, ``Environmental Program.'' It is the determination of FmHA 
that this action does not constitute a major Federal action 
significantly affecting the quality of the human environment and in 
accordance with the National Environmental Policy Act of 1949, Public 
Law 91-90, an Environmental Impact Statement is not required.

Intergovernmental Consultation

    For the reasons set forth in the Final Rule related Notice(s) to 7 
CFR part 2015, subpart V, programs 10.415 Rural Rental Housing Loans 
and 10.427--Rural Rental Assistance Payments are subject to Executive 
Order 12372 which requires intergovernmental consultation with State 
and local officials.

Paperwork Reduction Act

    The information collection requirements contained in these 
regulations have been approved by the Office of Management and Budget 
(OMB) under the provisions of 44 U.S.C. chapter 35 and have been 
assigned OMB control numbers 0575-0042 and 0575-0033 in accordance with 
the Paperwork Reduction Act of 1980 (44 U.S.C. 3507). The information 
collection contained in 0575-0047 will not become effective until 
approved by OMB. Please send written comments to the Office of 
Information Regulatory Affairs, OMB, Attention: Desk Officer for USDA, 
Washington, DC 20503. Please send a copy of your comments to Jack 
Holston, Agency Clearance Officer, USDA, FmHA, AG Box 0743, Washington, 
DC 20250.

Programs Affected

    These programs/activities are listed in the Catalog of Federal 
Domestic Assistance under Numbers 10.415, Rural Rental Housing Loans 
and 10.427, Rural Rental Assistance Payments.

Background

    During its audits of FmHA's identity of interest construction cost 
certification process, the Office of Inspector General found many 
instances where borrowers were taking advantage of loopholes in FmHA 
regulations. This resulted in the loss of Government funds through 
excess profit being paid to paper contractors, failure of the borrowers 
to reveal identities of interest with related parties, failure on the 
part of CPA's to adequately perform cost certifications, and numerous 
other discrepancies of varying severity, all of which have had 
detrimental effects on the program. OIG reviewed the proposed changes 
to the regulations and voiced its support for the proposed changes as a 
mean for reducing fraud, waste, and abuse in the 515 program.

Discussion of Comments

    The proposed rule, published in the Federal Register (57 FR 27379-
27394) on June 19, 1992, provided for a 60-day comment period ending 
August 18, 1992. One hundred and twenty-one comments were received 
during the comment period from the public and from FmHA field 
employees.

Comments

Implementation Proposal

    FmHA has stated that all preapplications and applications on hand 
will be subject to the final rule with the exception of applications 
whose plans and specifications have been finalized.
    Several persons agreed that preapplications and applications not be 
``grandfathered'' except for those which have received an AD-622 and 
which are within the District's 150 percent loan approval authority. 
Other persons objected to not ``grandfathering'' because of the expense 
already incurred in developing an application.
    Since applicants have already invested substantial sums of money in 
the development of building plans, FmHA has reconsidered this position. 
Building plans included with preapplications which have been issued an 
AD-622 inviting a formal application will not be affected; all other 
material associated with preapplications will be subject to the 
provisions of the final rule.

FmHA Instruction 1924-A

1. Section 1924.10 (c)(2)(i)
    Comment: Comments were received concerning the requirement that all 
transfers of funds between line items would require the approval of the 
servicing official using Form FmHA 1924-7. The general feeling is that 
estimates are merely estimates and will fluctuate during the 
construction period. To require the servicing official to approve 
change orders for every line item change would cause a major paperwork 
burden on both the contractor and FmHA.
    FmHA response: The Agency recognizes the volume of paperwork and 
delay involved with this requirement. FmHA will, instead, implement a 
means to flag significant variances in line item costs. Increases or 
decreases at or above a 15 percent threshold will require documentation 
from the borrower to justify the differences. The State Director will 
also have the authority to require documentary justification for less 
than 15 percent variances if he/she deems it necessary. The 
documentation will be required at the time the project is cost 
certified so that construction will not be delayed.
2. Section 1924.13(a)(3)
    Comment: Most persons agreed that architectural fees should be 
reduced when less than full architectural services are provided. It was 
suggested that it would be appropriate to establish a range of fees 
covering a range of similar services. It was also pointed out that an 
acceptable design in one place can involve a redraw in others due to 
local code interpretations.
    FmHA response: The intent of this requirement is for those 
instances where the applicant uses a set of plans that has previously 
been used. Even if a new site requires some modification to adapt the 
building to the site, it will not require a complete redraw of the 
building. While there can be no hard and fast rules set by Washington 
as to the degree of revision needed to qualify the architect for full 
services, this can be determined at the State level. Compensation is 
expected to reasonably represent the value of the architect's services 
to the owner.
3. Section 1924.13(e)(1)(iii)(B)(3) and 1924.13(e)(2)(i)(D)
    Comment: A number of persons suggested that more training be 
provided to FmHA field staff in analyzing the financial statement to 
determine whether there is sufficient ``financial strength to carry out 
all phases of construction.'' Another suggestion was that FmHA require 
a performance and payment bond from all contractors, in which case the 
credit worthiness will have been determined by a surety company. 
Several persons pointed out the fact that credit reports do not reflect 
the financial strength of the contractor.
    FmHA response: FmHA has completed phase one of a two phase training 
program in the proper analysis of financial reports. The training is 
being conducted by an outside accounting firm and involves State, 
District, and National Office personnel. We recognize that requiring a 
payment and performance bond from all contractors would probably 
eliminate the small yet qualified contractor from participating in the 
515 program. Based on the comments that a credit report is not the 
vehicle through which financial strength can be determined, FmHA will 
require that each contractor provide a financial statement of its 
operations. The financial statement will be analyzed to determine if 
the contractor has the financial strength to pay construction bills 
prior to obtaining draws from the lender. Language relating to the 
submission of a financial statement has been added to this section. A 
credit report will still be required from all contractors.
4. Section 1924.13(e)(1)(iv) and 1924.13(e)(2)(i)(G)
    Comment: There was some opposition to eliminating the price of cost 
certifications from the contract.
    FmHA response: FmHA deleted this cost from this section because it 
intended to contract for cost certifications itself. This would have 
eliminated the need for including the cost in the construction contract 
since they would be paid from Agency funds. It has now been determined 
that the Agency will be unable to contract for all cost certifications, 
so the previous language pertaining to cost certification expenses has 
been restored to this section to cover those situations where the 
borrower will be required by FmHA to obtain the certification.
5. Section 1924.13(e)(1)(v) and 1924.13(e)(1)(v)(E)
    Comment: Several persons agreed with the proposal that FmHA 
contract directly for cost certifications. The most consistently 
expressed concern was about the delay in the Government contracting 
process, resulting in increased interim interest expense. There was 
also some concern about the burden this proposal would place on FmHA. 
There was a suggestion to have FmHA contract with a CPA to review and/
or audit a certain percentage of the cost certifications within the 
State each year. Also, one person suggested that FmHA allow contracts 
between the CPA and the contractor when the CPA can certify that he/she 
has no other relationship with the contractor except for the cost 
certification. Comments from other persons stated that the ongoing 
working relationship between the borrower and the CPA is a definite 
advantage since the CPA is familiar with the accounting system and 
procedures of the borrower. They felt that having full-time access to 
the CPA who is responsible for monitoring the construction cost 
recording process would allow for timely maintenance of records. An 
FmHA-contracted auditor would not have this familiarity with the 
borrower's books. One respondent suggested that FmHA publish a guide to 
tell CPA's how FmHA wants the cost certifications performed and 
reported. One suggestion is that instead of contracting for cost 
certifications directly, FmHA should strengthen its ability to debar an 
incompetent CPA. Another respondent suggested that FmHA establish a 
list of CPA's who have been designated as acceptable for cost 
certification. One suggestion was that FmHA make a judgment of whether 
the borrower's cost certification is satisfactory instead of hiring the 
CPA directly.
    FmHA response: FmHA has worked with the Office of Inspector General 
to develop an audit program which CPA's will follow in performing cost 
certification audits. During recent OIG audits of cost certifications 
prepared on FmHA-financed rental housing projects, it was discovered 
that many CPA's were not maintaining the independence required by 
generally accepted auditing standards. It is obvious from some of the 
comments that some CPA's who are cost certifying construction costs 
have also been involved in the maintenance of the borrowers' 
construction records. FmHA will not have sufficient contracting funds 
to cover the cost of all certifications; therefore, it anticipates 
contracting for all certifications on loans of $1.5 million and over 
and a random sampling of all other loans. Details will have to be 
worked out in the contracting process to prevent undue delay in closing 
loans. In the event FmHA does contract for a cost certification, the 
borrower will not be responsible for providing a certification since 
that would duplicate energies and expenses. Any funds earmarked in the 
loan for cost certification but which are not needed because of an 
FmHA-contracted certification will be returned on the loan and may not 
be used for any other purpose.
6. Section 1924.13(e)(1)(v)(A)
    Comment: There was some confusion about whether FmHA would be 
contracting with the CPA who examines the borrower's accounting system 
or just with the CPA who performs the cost certification. A suggestion 
was offered that the borrower provide a written assertion that it has 
an accounting system which complies with the regulations. The cost 
certification CPA would then report on the validity of the assertion.
    FmHA response: It was the intent of this proposal that the 
borrower's CPA be responsible for verifying that the borrower's 
accounting system meets the requirements of the regulation so that this 
responsibility can be removed from FmHA field personnel. Since the 
Agency does not have accountants on staff, we do not feel we have the 
expertise to adequately check the borrower's accounting system. We 
agree with the suggestion that the borrower be allowed to provide a 
written assertion on the accounting system and that the cost 
certification CPA report on its validity. This section has been 
rewritten to incorporate that suggestion.
7. Section 1924.13(e)(1)(v)(B), 1924.13(e)(2)(iv), and 
1924.13(e)(2)(viii)(B)
    Comment: There was a question as to whether FmHA intends to reduce 
builder's profit when costs of line item are increased. Another 
respondent wondered if it is the intent of FmHA to restrict the amount 
of each line item to the estimated amount. Several persons objected to 
the restriction of general requirements to the estimated amount. One 
respondent recommended that any cost savings from project construction 
be returned on the loan and that the loan be reamortized to reflect a 
decrease in tenant rent.
    FmHA response: FmHA intends that builder's profit be reduced when 
the total costs of the line item costs exceed their estimates and would 
result in an increase in the contract amount. The amounts for general 
overhead, profit, and general requirements will be restricted to their 
estimated amounts, not the line items to their estimated amounts. FmHA 
believes that the estimates for general requirements can be accurately 
determined prior to the start of construction and not deviate 
significantly thereafter. We do not feel this would result in an undue 
burden on the borrower. A refund of loan funds can be used to 
reamortize the loan if it can be shown that the amount refunded will 
reduce the rents and an exception to the 10 percent requirement has 
been granted by the National Office.
8. Section 1924.13(e)(1)(v)(C) and 1924.13(e)(2)(viii)(A)
    Comment: There was some objection to requiring the borrower to 
agree that the tests conducted will include FmHA audit requirements. 
One respondent has recommended that the language be changed to refer to 
FmHA 1924-A instead of ``FmHA regulations'' and has provided FmHA with 
suggested language for this section.
    FmHA response: Because of the problems with how cost certifications 
are conducted, as revealed by OIG, FmHA felt it necessary to institute 
additional instructions to the CPA/LPA's which are intended to provide 
uniformity in the examination of construction costs. FmHA sought advice 
and assistance from the American Institute of Certified Public 
Accountants in developing the additional instructions referred to as 
the Audit Program. The Audit Program will be available in FmHA offices. 
It is FmHA's intent that the borrower recognize the Audit Program and 
to ensure that the auditor include its requirements in the cost 
certification process. The language of this section has been reworded 
as recommended by AICPA. FmHA has changed the reference from FmHA 
regulations to FmHA Instruction 1924-A.
9. Section 1924.13(e)(1)(v)(D)
    Comment: One respondent objects to the auditor having to certify 
that he/she has no financial interest in or with the applicant/owner-
builder, architect, engineer, attorney, contractor, etc., since 
Government Auditing Standards prohibit such an identity of interest. 
Two respondents pointed out an inconsistency in the suggested CPA 
opinion letter since one paragraph refers to Generally Accepted 
Government Auditing Standards (GAGAS) and another refers to General 
Accepted Accounting Principles (GAAP).
    FmHA response: Even though the Government Auditing Standards 
prohibits identities of interest between CPA's and the applicant, 
architect, engineer, attorney, contractor, etc., OIG audits have 
revealed apparent close relationships exist between some CPA's and 
borrowers. Certain CPA's have not maintained an independence from the 
borrower as required by Government Auditing Standards. There is no 
inconsistency in the suggested opinion letter since GAGAS pertains to 
the audit of the construction costs and GAAP pertains to the accounting 
system which the borrower uses in recording construction costs. OIG has 
submitted a sample auditor's report which is incorporated in the Audit 
Program and available in any FmHA office.
10. Section 1924.13(e)(1)(v)(F)
    Comment: The opinion was expressed that the CPA who reviews the 
borrower's accounting system be allowed to cost certify. Also, costs 
will be duplicated if the borrower has to hire a CPA in addition to 
FmHA contracting for CPA services. There was objection to denying the 
right of a CPA to cost certify when that CPA is currently handling the 
contractor's accounting.
    FmHA response: It was originally FmHA's intent that the CPA who 
reviews the borrower's accounting system not cost certify the project 
after construction. This was primarily due to the fact that OIG audit 
findings revealed a lack of independence between CPA's and borrowers. 
We have reconsidered this prohibition and will allow the same CPA who 
sets up or examines the borrowers accounting system to certify 
construction costs. However, the CPA who provides any accounting 
services to the borrower during construction will not be allowed to 
cost certify the project. To do so would be a violation of rules of 
independence set forth in Government Auditing Standards.
11. Section 1924.13(e)(1)(v)(G)
    Comment: There was one objection to using the new forms since the 
respondent felt FmHA already has an identity of interest statement in 
use.
    FmHA response: The purpose of the new forms is twofold; one to 
require all borrowers to disclose all identities of interest and the 
other to identify ``paper companies.'' The identity of interest 
statement itself has been changed to also include other related 
parties. The forms also provide notification to all affected parties of 
the penalty for falsifying the documents. FmHA feels these forms are 
needed.
12. Section 1924.13(e)(1)(v)(H)
    Comment: One respondent objected to having to report a discount or 
rebate when the original line item costs were based on the discounted 
amount. Another person offered the rationale that rebates and discounts 
are incentives to buy ``right'' and to pay bills on time and that FmHA 
is attempting to remove these incentives. One respondent requested 
clarification of the next to last sentence in this section. The general 
objection was voiced about reducing profit to agree with the reduction 
in line item costs of construction. One person felt that contractors 
would use the pretext of obtaining a rebate or discount in order to not 
contribute additional funds to cover the increase in line item costs. 
One respondent supported this section.
    FmHA response: After due consideration, FmHA has decided that this 
section more appropriately pertains to multiple advance loans where 
payments are made by FmHA and the amount of any discounts or rebates 
will be deducted before invoices are paid. If discounts or rebates are 
given after the invoices are paid, the funds will be returned to the 
supervised bank account. Therefore, this section has been amended to 
delete reference to discounts and rebates.
13. Section 1924.13(e)(1)(v)(I)
    Comment: The reference to the HUD regulatory language apparently 
has caused some confusion since it was merely referenced. One 
respondent wanted to know if the general contractor has to hammer nails 
in order to be performing work. Another respondent felt that 
subcontracting out all or nearly all of the work is a typical and 
accepted practice. One respondent suggested that this provision be 
waived if it can be demonstrated that it is to the benefit of the 
property. One person questioned whether this provision will pertain to 
everyone or just in those cases where an identity of interest exists; 
if it pertains to everyone, then this section should be taken from the 
cost certification portion of the regulation. One respondent requested 
that we provide a definition of ``actual construction.'' Two 
respondents requested that a distinction be made between work on new 
construction and work on a rehabilitation. One respondent agreed with 
this section.
    FmHA response: To eliminate confusion, the reference to the HUD 
regulation has been removed from this section. OIG audits have found 
repeatedly that persons who identified themselves as the construction 
contractor were not qualified to build the project or, for some reason, 
did not build the project. They, instead, subcontracted out all or most 
of the construction and still took a full builder's profit. FmHA 
adamantly opposes the payment of profit to anyone who does not perform 
the full range of duties of a general contractor. This section does not 
prohibit a contractor from subcontracting out any or all of the work as 
long as that contractor does not receive a builder's profit. The Agency 
has no objection to the contractor being paid for services rendered. 
FmHA does not foresee any situation where waiver of this provision will 
benefit the property. This section pertains only to identity of 
interest borrowers and will remain in this location. For purposes of 
clarification, we are defining ``actual construction'' to mean ``work'' 
as defined in A.I.A. documents: ``* * * labor, materials, equipment, 
and services provided by the contractor to fulfill the contractor's 
obligations.'' Irrespective of whether the project is new construction 
or rehabilitation, the general contractor should not expect to receive 
a builder's profit if he/she has not performed the full ranges of 
responsibilities of a general contractor.
14. Section 1924.13(e)(1)(v)(J)
    Comment: There was agreement that FmHA implement these new forms. 
One respondent suggested that more specific requirements be added such 
as years in business, work performed other than on FmHA-financed.
    FmHA response: The new Form FmHA 1944-31 will require the entity to 
disclose number of years in business. We do not feel that 
identification of the work performed on other than FmHA-financed 
projects is necessary since the entity is certifying that it is an on-
going business.
15. Section 1924.13(e)(1)(vii)(B)(1) and 1924.13(e)(2)(iii)(A)
    Comment: One respondent expressed an opinion that this section will 
eliminate the smaller developers. There was some feeling that this 
would discourage the participation of owner-builders or that it will 
cause undue delay in the processing of the preapplication. One 
respondent recommended that the determination of whether to grant an 
exception to competitive bidding be made at the application stage 
rather than at the preapplication stage. One respondent misinterpreted 
this section to mean competitive bids would be granted rather than the 
negotiated contracts.
    FmHA response: The only new language added to this section requires 
that FmHA document, in writing, the examination required prior to the 
State Director granting an exception to competitive bidding. We do not 
feel that small developers are any more at risk now than before the 
change since the requirement is not new to this revision. FmHA agrees 
that the determination of whether to grant an exception to competitive 
bidding be made during the application stage and have changed the 
language to reflect this requirement. The correct meaning of this 
section is that negotiated contracts may be allowed once the State 
Director has determined all requirements for granting an exception to 
competitive bidding have been met.
16. Section 1924.13(e)(2)(i)(G)
    Comment: One respondent wanted to know under what circumstances 
will cost estimation services be required and asked where else in the 
regulation this subject is discussed. Another respondent raised issues 
which appear to be unrelated to this section and we could not determine 
to which section the comment referred. Other comments pertain to the 
deletion of cost certification fees which was previously discussed 
under Sec. 1924.13(e)(1)(iv).
    FmHA response: The existing regulation contained a provision for 
cost estimation services to be used if FmHA did not agree with the 
owner-builder's estimate. This was seldom, if ever, imposed. Our recent 
test of using estimating services proved to be unreliable and 
inconsistent. The reference to cost estimation has been removed from 
the regulation.
17. Section 1924.13(e)(2)(iv)
    Comment: One respondent suggested that allowances for general 
overhead, general requirements, and a builder's profit be based on a 
regional cost rather than on a State average.
    FmHA response: This section states that the amounts may be 
determined by local investigation and also from HUD data for the area. 
It does not mention a State average.
18. This Respondent Refers to 1924.13(e)(1)(vii)(D)
    There is no such section in FmHA Instruction 1924-A.
19. Section 1924.13(e)(2)(viii)
    Comment: One respondent asked if the requirement that projects have 
their costs ``audited by FmHA'' refers to cost certification contracted 
by FmHA, OIG or other FmHA audit. Another respondent points out that 
this section contains a cost certification cutoff for projects of 
$350,000 or more and expresses an opinion that there should be no 
difference between identity of interest and owner-builder. One 
respondent points out that a FmHA 1924-13 is mandatory for all loans of 
over $350,000 and that if the loan is publicly bid this form should not 
be mandatory.
    FmHA response: The reference to ``audited by FmHA'' falls within 
the same provision that was discussed earlier concerning FmHA 
contracting for all cost certifications. The respondent is correct in 
his observation concerning the $350,000 cutoff for owner-builders. All 
owner-builders are identity of interest entities which automatically 
require a cost certification. The reference to $350,000 has been 
removed from this section. FmHA regulation 1944-E now requires that all 
applicants submit Form FmHA 1924-13 to facilitate the tracking of line 
item costs in the Agency's upcoming computerized cost tracking system. 
This applies to all applicants regardless of whether or not an identity 
of interest is involved.
20. Section 1924.13(e)(2)(viii)(B)
    Comment: One respondent suggested that further clarification be 
added to the section regarding amounts for general overhead, general 
requirements, and builder's profit as being treated as individual and 
separate line items amounts or whether all three should be combined, 
thus eliminating the need for Administrative Notice explanation. 
Another comment did not appear to pertain to this section.
    FmHA response: The Administrative Notice issued on this subject 
addressed the percentages for establishing separate amounts for general 
overhead, general requirements, and builder's profit; this section 
refers to the dollar amounts which are established as a result of the 
percentage calculation. The FmHA 1924-13 requires that these three 
items be listed separately. This section refers to establishing dollar 
amounts for general overhead, general requirements, and builder's 
profit and that actual costs for those three items will not exceed 
their dollar estimates. Language addressing the allowable percentages 
for general overhead, general requirements, and builder's profit has 
been added to Sec. 1944.215(a)(1) of subpart E of part 1944.
21. Section 1924.13(e)(2)(viii)(C)
    There was one comment and the respondent expressed agreement with 
this section.
22. Section 1924.13(e)(2)(viii)(D)
    Comment: One respondent expressed agreement with this section. 
Another respondent requested clarification of the reference to HUD 
regulation.
    FmHA response: The reference to the HUD regulations has been 
dropped from this section as discussed under Sec. 1924.13(e)(1)(v)(I), 
above.

1944-E

1. Section 1944.211(a)(3)
    Comment: A number of objections were expressed to limiting the 
number of preapplications to five. Several respondents supported this 
proposal. The reasons were many and too numerous to list. One 
respondent suggested that the limitation be based on applications and 
not preapplications and that the number be controlled on a State basis. 
Many persons suggested that the number of preapplications be based on 
the financial capacity of the applicant and not on the number of 
preapplications. Other recommendations include a limit of from 3 to 15 
preapplications; 5 preapplications and a nationwide limit of 10; 10 
preapplications per District; 15 or 20 with no more than 5 funded and/
or under construction at one time; and 10 preapplications nationwide 
except for preapplications accompanied by a deposit equal to 1 percent 
of the loan. Other respondents recommended no limit be set for 
preapplications or applications. Several persons recommended returning 
preapplications which cannot be funded within a set period of months.
    To illustrate his objection to limiting the number of 
preapplications, one respondent sent several photographs of FmHA-
financed apartment complexes which were not being properly managed. The 
respondent alleged that these apartments were owned by small developers 
and the photographs serve as an example of what would happen to the 
section 515 program if only small developers could participate.
    FmHA response: The majority of comments were overwhelmingly opposed 
to restricting the number of preapplications. Therefore, the Agency is 
not undertaking any changes to this section at this time.
    FmHA was concerned over the photographs and investigated the 
respondent's claim. In all cases, FmHA was taking action to correct the 
management deficiencies. In almost all cases, the developers of the 
subject apartments were not small developers. In the one case where the 
developer would be considered a small developer, the State did not feel 
the management problems were due to the fact the developer was not a 
large entity. Therefore, we do not consider this particular objection 
to the proposed rule to have merit.
2. Section 1944.211(a)(5)
    Comment: One respondent expressed an opinion that requiring 
evidence that the borrower has or can obtain the 3 percent borrower 
contribution at the preapplication stage is premature and should not be 
required until prior to obligation.
    FmHA response: The ability of the borrower to furnish the 
contribution is a criterion of eligibility. The Agency feels that 
eligibility must be established at preapplication stage. If that 
requirement were to be delayed until the loan is ready to be obligated, 
the applicant and FmHA would have invested far too much time and money 
to have the applicant determined not eligible. The 3 percent 
contribution was increased to 5 percent by the Community Development 
Act of 1992 for all projects whose members will receive benefits from 
Low Income Housing Tax Credits. The regulation has already been changed 
to reflect the increase in the equity contribution requirement.
3. Section 1944.211 (a)(5)
    Comment: Two respondents expressed the opinion that applicants 
should be required to furnish the 3 percent borrower contribution from 
its own resources.
    FmHA response: Currently, borrowers have no personal financial 
obligation to serve as an impetus to seeing that the project operates 
successfully. We agree that such an obligation will encourage continued 
interest in overseeing the well-being of the project and it makes sense 
from a business standpoint. Therefore, FmHA agrees that applicants 
should furnish the 3 or 5 percent contribution from their own resources 
and have changed this section to reflect that requirement.
4. Section 1944.211(a)(7)(i)
    Comment: Several comments were received concerning the requirement 
that the applicant provide sufficient cash to cover start-up costs and 
that a list of such materials and equipment be provided. It was felt 
that this was an attempt to disallow the use of letters of credit to 
cover the O&M expenses.
    FmHA response: Currently, regulations allow borrowers to provide a 
letter of credit to cover the total amount needed for operating and 
maintenance expenses. FmHA has experienced a reluctance on the part of 
borrowers to draw on the letters of credit since doing so will incur 
interest expenses for which they are liable. Thus, there have been many 
instances where there were insufficient funds to cover needed start-up 
costs. Requiring the borrower to provide the requirement in cash will 
ensure the availability of adequate funds with which to cover these 
expenses. The Housing Act of 1949, as amended, states that ``The 
Secretary may require that the initial operating reserve under this 
section may be in the form of an irrevocable letter of credit * * *''. 
This language provides the Agency the option of whether to require 
letters of credit or to require the initial O&M in cash. FmHA has 
determined that more benefits will be derived by projects if cash is 
furnished for the operating reserves and, for this reason, has decided 
not to accept letters of credit.
5. Section 1944.212(b)
    Comment: A number of comments were received concerning restricting 
rehabilitation loans to no more than 5 percent of the loan for new 
construction. Several of the respondents expressed their support for 
placing this limit on rehabilitation loans. Also, a couple of 
respondents suggested that FmHA eliminate purchase and rehabilitation 
of historic buildings altogether. Several respondents did not favor 
this proposal and misconstrued its intent as an attempt to eliminate 
rehabilitation of historic buildings.
    FmHA response: The cost for purchasing and rehabilitating existing 
buildings has increased noticeably within the recent past and has, in 
some cases, exceeded the amount needed for constructing new units. FmHA 
feels it appropriate to establish a ceiling to ensure maximum use of 
loan funds. The excess cost of rehabilitation would be better spent to 
finance more units in other areas of need. Therefore, the Agency feels 
that a limit should be placed on the amount of Government funds being 
expended for rehabilitating historic buildings. While the Agency does 
not wish to prohibit the purchase and rehabilitation of historic 
buildings, it feels that a ceiling is needed to prevent unlimited funds 
from being used for this purpose. The proposed regulation does not 
prohibit the borrower from infusing additional cash from its or other 
sources in order to fully fund the purchase and rehabilitation. FmHA's 
first consideration must be to providing rental units to its 
beneficiaries at the lowest cost to the tenants.
6. Section 1944.212(c)(1)
    Comment: One respondent expressed an opinion that this section 
limits the basis of FmHA's maximum loan being 97 percent of total 
development cost or appraised value. Another respondent stated it does 
not appear there is a specific provision to accomplish what is required 
in this section. One respondent suggested adding clarification that 
FmHA can lend the present market value of the site ``as improved'' and 
that the cost of the improvements could not be released until all 
improvements were in place. One respondent recommended the section be 
revised to state the lower of the appraised value or purchase price 
will be used to determine total development cost and the applicant's 
initial investment. Another respondent recommended we restore the 
original language of this section. One respondent agreed that loan 
funds used to purchase land may not exceed the estimated market value 
as established by an appraisal.
    FmHA response: The only changes made to this section are the 
reference to FmHA Instruction 1922-B and deletion of the words ``in 
excess of estimated market value'' in the last sentence. These changes 
do not alter how the loan is calculated. The purchase price of land is 
not the basis for establishing the applicant's initial investment. The 
FmHA loan is limited to the development cost or the security value of 
the project, whichever is less; the applicant is responsible for the 
equity contribution whether it is in the form of land, cash, or a 
combination of both. After considering the comments, we feel that this 
section is confusing as written since it should be addressing the 
amount of loan funds which can be used to purchase land and should not 
include discussion of how the purchase price affects the applicant's 
initial investment. The last sentence has been removed.
7. Section 1944.212(c)(2)
    Comment: One respondent suggested that the existing language be 
restored to this section.
    FmHA response: The first sentence of the existing paragraph was 
removed because it already exists under Sec. 1944.213(c)(10).
8. Section 1944.212(c)(3)
    Comment: One respondent voiced the opinion that the density 
requirements referred to in Sec. 1944.215(a)(5) are not definitive. 
Another respondent suggested that FmHA define excess land. Another 
respondent felt that this section is in conflict with 
Sec. 1944.215(a)(6) and should be deleted. One respondent agreed with 
the section as long as consideration is given to local zoning 
requirements.
    FmHA response: FmHA feels that excess land is adequately defined in 
this section and in Sec. 1944.215(a)(6). We do not agree that this 
section conflicts with Sec. 1944.215(a)(6). Section 1944.215(a)(6) 
states that local zoning ordinances and, in extreme cases, the site 
size, shape, or condition will be the determining factors in arriving 
at site density.
9. Section 1944.212(d)
    Comment: There were a number of suggestions concerning the 
establishment of a range of costs for offsite facilities. One 
respondent recommended that all offsite costs be eliminated from the 
loan. It was pointed out by several respondents that States have not 
approved any off-site facility costs. It was also suggested that each 
situation is unique and should be judged on its own merits and not be 
compared with past performance. One respondent felt this would place an 
undue burden on FmHA and that establishing a range would not prove 
anything since the bottom line must be the actual ``as developed'' 
value of the site.
    FmHA response: FmHA agrees that every situation has to be judged on 
its own merit and that it would be impractical to try to establish a 
range of costs for offsite facilities. The language has been changed to 
delete this requirement.
10. Section 1944.212(g)
    Comment: There was generally an expression of agreement with the 
addition of blinds as an eligible loan purpose. One respondent, 
however, suggested that we also include shades with this provision. One 
respondent wanted to know if individual washer/dryer hookups could be 
interpreted to mean ``laundry facility.'' Another respondent voiced an 
opinion that washer/dryer hookups in addition to a central laundry 
facility increases marketability of rental units.
    FmHA response: FmHA has no objection to including shades in this 
provision and has amended the language accordingly. Laundry facilities 
are defined as the actual washers and dryers facilities available to 
all of the tenants and not just washer and dryer hookups. Washers and 
dryers owned by individual tenants are not available to all tenants and 
cannot be considered as ``laundry facilities.'' FmHA stands by its 
previous position regarding the prohibition of placing washers and 
dryers in individual units when a central laundry facility is provided 
unless it is customary for the area for the size of project and type of 
housing involved. Washer and dryer hookups are an additional expense to 
overall project costs and, in the majority of cases, are not used by 
the tenants. Additionally, there have been problems with the hookups 
leaking and causing water damage to the units.
11. Section 1944.212(i)
    Comment: There were numerous objections to disallowing certain fees 
when the borrowing entity will receive low income housing tax credits, 
primarily because the end result will be an increase in the borrower's 
contribution. Other respondents felt that if certain items were 
required by FmHA, then those items should be funded. One respondent 
suggested that FmHA automatically increase the equity requirement for 
low income housing tax credit projects to 5 percent rather than to 
eliminate certain fees and charges. One respondent suggested that the 
intent be clarified to mean the legal fees associated with closing the 
FmHA loan and not the interim lender loan. Another person suggested 
that all non-low income housing tax credit projects receive an 
additional 10 points in the rating criteria. One respondent felt that 
this provision would reduce loan costs and thereby maximize the State's 
funding allocation.
    FmHA response: The Community Development Act of 1992 increased the 
equity contribution to 5 percent for borrowers whose members will 
receive benefits from Low Income Housing Tax Credits. The regulation 
has already been changed to reflect this increase. The original 
language pertaining to related costs has been restored. Legal fees 
pertain to the costs associated with the FmHA loan closing only; 
clarification has been added to the section. FmHA does not agree with 
the suggestion to allow an additional 10 points for non-low income 
housing tax credit projects. The purpose of the priority points is to 
direct funding to the areas of greatest need and the lack of tax 
credits is not an indication of need.
12. Section 1944.212(j)
    Comment: There were several respondents who expressed opposition to 
allowing payment for assistance to nonprofit groups because of the 
inequity in handling profit vs. nonprofit applicants.
    FmHA response: FmHA published this section to correct a 
typographical error in the original section; however, the Agency feels 
that the payment for technical assistance is appropriate for nonprofits 
since they must rely on their own resources which, in some cases, are 
slim or nonexistent.
13. Section 1944.213(b)(1)
    Comment: One respondent understood this section to mean the 
nonprofit organization may provide the initial operating capital and/or 
relocation costs incurred and suggested that the section be revised to 
include relocation costs in the loan.
    FmHA response: This section states that the loan may provide for 
the development cost or the security value of each project, whichever 
is less, plus the 2 percent O&M and/or the relocation costs. This 
provision allows for the inclusion of relocation costs in the loan.
14. Section 1944.213(b)(2)
    Comment: While 3 respondents agreed with the proposed computation 
of the loan amounts, numerous others disagreed. Most felt that the 
Agency was attempting to increase the borrower's equity contribution.
    FmHA response: FmHA has removed the examples from this section and, 
instead, will provide instructions to its staff in how loans should be 
calculated in a new Exhibit A-12. The Exhibit provides administrative 
guidance only and is not being published with this document. A copy is 
available in any FmHA office.
15. Section 1944.213(c)(10)
    Comment: One respondent expressed an opinion that there should be 
an exception to this provision which allows the person who has owned 
land for a period of at least 3 years to recover costs associated with 
the increase in value and betterment of the site. Another respondent 
suggested the restriction be expanded to provide that there be no 
common interest for at least 3 years and that the option be with the 
owner of public record; an exception could be made for subsequent loans 
on adjacent property.
    FmHA response: FmHA does not agree with this suggestion. 
Regulations, except in the case of a broadly-based nonprofit 
organization, prohibit the use of loan funds to purchase land from the 
applicant or a member of the applicant organization. In the case of a 
nonprofit organization, the appraisal will determine the value which 
can be included in the loan. We think the suggestion concerning common 
interest has merit and have changed this section to add a 3-year 
provision.
16. Section 1944.213(c)(12)
    Comment: One respondent felt that this section is no longer needed 
in light of the provisions of Sec. 1944.211(a)(7) (i) and (ii) which 
would require the applicant to put up in cash the amount necessary for 
the initial 2 percent O&M.
    FmHA response: FmHA agrees with this comment and the section has 
been deleted.
17. Section 1944.213(d)
    Comment: A few respondents expressed their opinion that this 
provision would be burdensome and time-consuming. One respondent 
pointed out that the expense of a market study is always incurred prior 
to the applicant's filing a preapplication. Another respondent pointed 
out the language of this section does not allow for predevelopment 
loans from nonprofit organizations as was originally intended.
    FmHA response: Since most borrowers are familiar with the process 
and are aware of what must be done during the preapplication and 
application phase, obtaining written verification from FmHA should pose 
no undue delay. OIG strongly recommended that FmHA be aware of the 
applicant's intention to incur debts before they are actually incurred 
to preclude the appearance of giving blanket approval for all such 
expenses. We agree that the language does not allow for predevelopment 
loans from nonprofit organizations and the language has been amended to 
correct this omission. We have also exempted market studies from the 
prior written approval requirement since they must be completed prior 
to filing a preapplication.
18. Section 1944.213(e)(1)
    Comment: Several persons objected to this section because of the 
delay it would cause during the construction process. Some suggested 
that FmHA require post-approval instead of pre-approval to avoid such 
delays.
    FmHA response: The Agency feels that obtaining pre-approval from 
the District Office will not sufficiently hamper the construction 
process if the contractor and borrower react in a timely manner. The 
only two occurrences which will allow an increase in per unit cost is 
design changes by FmHA or State or local jurisdictions or changes in 
financing approved by FmHA. Neither of these events would be construed 
as an emergency.
19. Section 1944.215(a)
    Comment: Two respondents expressed agreement with this section. 
Another respondent voiced an opinion that to require more expensive 
building materials and, even though maintenance costs will be less, is 
contradictory to cost containment goals.
    FmHA response: The Agency has witnessed what happens when cheaper 
building materials are used to initially control costs. The results 
have been high maintenance costs over the life of the materials and the 
ultimate replacement of the materials. While construction costs may be 
lower using the cheaper building materials, these savings are more than 
overshadowed by the high maintenance costs necessary to prolong the use 
of the materials. FmHA strongly advocates the use of low maintenance 
and long life materials in its construction.
20. Section 1944.215(a)(1)
    Comment: There were several comments expressed about the costs 
being ``locked in'' to either our cost tracking system or to the 
Marshall & Swift estimates, thereby not allowing any inflation 
increases. It was also noted that projects with abnormally high or low 
costs should not be entered into the system and that only newer (one 
year old) projects be tracked. It was felt that the borrower should not 
be responsible for resolving differences between a proposed project's 
costs and those costs in the FmHA tracking system or in the Marshall & 
Swift estimates. Another respondent suggested that the tracking system 
allow for a comparison of bedroom sizes rather than project to project 
comparison. One respondent felt that the tracking system should provide 
for a distinction between new construction and rehabilitation.
    FmHA response: The new cost tracking system will allow FmHA to 
track by line item the costs of construction. For instance, the final 
estimated cost of concrete for a proposed project will be recorded in 
the system at the time the loan is obligated. Once the project has been 
built and the costs are certified (identity of interest projects), the 
certified cost of concrete will also be recorded in the system and will 
become the basis for establishing a benchmark on costs. This should 
take into consideration the inflationary escalation of costs during the 
construction period. Thereafter, the line item costs for each new 
proposal will be compared with the amounts recorded in the tracking 
system. Local FmHA offices will allow for future inflationary increases 
just as they do now. Only the projects received and processed after the 
tracking system comes on line will be entered. We intended that 
significant differences between an applicant's cost estimates and the 
estimates of our established tracking costs or Marshall & Swift be 
resolved since FmHA will not arbitrarily accept any estimates which 
appear out of line or unreasonable. We foresee the borrower's 
responsibility for resolving the differences in cost as either 
providing justification for the differences or taking whatever action 
is required to ensure the best estimates are being considered in the 
construction. This method of tracking construction costs will make no 
distinction between numbers of bedrooms or new construction vs. 
rehabilitation; costs will be tracked on a line item basis and not on a 
project basis.
21. Section 1944.215(a)(2)
    Comment: A few respondents suggested that FmHA establish timeframes 
for District and State Offices to follow during preapplication and 
application review processing. Another respondent suggested that the 
AD-622 cover only the authorization to develop plans and specifications 
and that the balance of the application not be pursued until receipt of 
the plans and specifications and after the appraisal is completed. It 
was felt that this would reduce the time between signing of the 
construction documents and the start of construction.
    FmHA response: From periodic assessments made of the multi-family 
housing program by FmHA's National Office, it is apparent that the 
field staff's time is being utilized to its fullest extent. The large 
volume of preapplications being filed has placed a considerable burden 
on the field, particularly when those preapplications which will not 
continue to be processed because of their rating must still receive 
some degree of attention. To place timeframes on the field for each 
step of processing would be unrealistic since they would most likely be 
impossible for the staff to meet. We do not agree that authorizing just 
the completion of plans and specifications would reduce the time 
between signing of the construction contract and the actual start of 
construction, since there are many other items needed to complete the 
application and these could not be addressed until we authorized the 
applicant to proceed to a full application. The cost estimates should 
be updated at the time the construction contract is signed so that the 
most up-to-date estimates are obtained prior to approving the loan.
22. Section 1944.215(a)(3)
    Only one comment was received and the respondent agreed with this 
section.
23. Section 1944.215(a)(4)
    Only one comment was received and the respondent agreed with this 
section.
24. Section 1944.215(a)(5)
    Comment: There were numerous objections to establishing a set 
number of units per acre because of the size, shape, and condition of 
sites.
    FmHA response: FmHA feels that more diligent efforts could be 
expended by applicants in locating more viable sites. Sites which have 
sections unsuitable for building should be avoided. However, if a 
situation exists where the only available site is of a size, shape, or 
condition which makes a portion unsuitable for building and the only 
alternative is to not provide units, then a request to the State Office 
for an exception to this density requirement may be considered. Such 
language has been added to the section.
25. Section 1944.215(a)(6)
    Comment: Several respondents expressed the opinion that hiring 
construction inspectors is unrealistic at a time when FmHA staff is 
being reduced. They also pointed out that delay in obtaining timely 
construction inspections by FmHA has been a problem and suggested 
including language in the regulation that would require necessary 
inspections within a reasonable timeframe.
    FmHA response: The hiring of construction inspectors is a 
suggestion which may or may not be possible to follow. If not, it may 
be possible for States to contract for these services. The comment 
about not having timely construction inspections by FmHA provides an 
appropriate case-in-point for adequate inspection coverages. This 
subject will be discussed at future training meetings with the field 
staff. FmHA feels that the proposed language is appropriate as 
proposed.
26. Section 1944.215(a)(7)
    Comment: There were several comments that the restriction of 
building design will result in all buildings being shaped like a box.
    FmHA response: FmHA feels this is an overreaction and that this 
section will not lead to the construction of boxes. We have observed, 
in many States, how a simple yet attractive design is an asset to the 
community. These types of simple designs do not deter potential tenants 
from seeking residency. The Agency feels that the design of some of the 
housing units now in existence have gone beyond what is necessary to 
provide decent, safe, and sanitary living units. The Housing Act of 
1949, as amended, specifies that ``no loan shall be made or insured * * 
* unless the Secretary finds that the construction involved will be 
undertaken in an economical manner and will not be of elaborate or 
extravagant design or materials.''
27. Section 1944.215(a)(8)
    Comment: Two respondents recommended against setting the building 
roof slope limits proposed in this section, one because of the snow 
loads in the northern States and the other because they could result in 
a building which lacks interest.
    FmHA response: FmHA agrees with the argument against setting the 
lower slopes in cases where there are heavy snow loads. The wording has 
been changed to allow the State Director to authorize a higher slope if 
needed to accommodate severe weather conditions. The Agency disagrees 
with the opinion that these slopes will result in a lack of building 
interest.
28. Section 1944.215(a)(9)
    Comment: Several respondents expressed agreement with this section. 
Several others felt that the use of repetitive designs would result in 
``cloned'' projects.
    FmHA response: FmHA does not feel that the use of repeat designs 
will have any detrimental effect on the aesthetic value of FmHA-
financed units. In fact, several States now require the use of repeat 
designs without detrimental effects. The National Office assesses the 
515 program in multiple States each year, which includes a visual 
inspection of the rental stock. We have not found the use of repeat 
designs to be offensive or boring in any State. FmHA feels that the 
submission of new designs for all projects needlessly increases the 
amount of Government funds needed since the amount of architectural 
fees is based on the level of services provided. Repeat designs will 
decrease the amount being paid for architectural fees since the use of 
``shelf'' plans will reduce the detailed architectural services needed.
29. Section 1944.215(a)(10)
    Comment: Several respondents stated that community room furniture 
should be included as an eligible loan expense; one respondent 
supported the inclusion of dining room furniture in congregate housing. 
Another respondent supported the inclusion of community rooms in family 
projects and garbage disposals. A few respondents suggested allowing 
sliding glass doors where patios/balconies are permitted. One 
respondent suggested adding whirlpools to developmentally disabled 
housing. Two respondents supported the inclusion of bay/box/picture 
windows. One respondent voiced support for prohibiting fire places, 
garages and covered parking. Two respondents supported this section.
    FmHA response: Community and congregate dining room furniture is 
the responsibility of the borrower and its expense should be covered by 
the initial O&M funds. Outdoor recreation facilities for family 
projects are allowable loan expenses and are intended to substitute for 
community room facilities allowed in elderly projects. The Agency 
considers community rooms to be an essential part of the daily living 
requirement for those elderly projects which can support the additional 
expense of the facilities. The obvious reason for not allowing 
community rooms in family projects is that family activities are not 
necessarily curtailed by age or climate and they are more mobile than 
elderly residents, which means their choice of entertainment can extend 
beyond their living accommodations. FmHA does not feel that garbage 
disposals are necessary and has recommended against financing them in 
the past. In addition to the initial cost of the disposal units, too 
often problems develop because of lack of care in what is processed 
through them, resulting in additional expense of the repairs. FmHA does 
not agree that sliding glass doors are necessary even when patios/
balconies are customary for the area. FmHA contends that if a 
developmentally disabled person requires whirlpool therapy, then it 
should fall within the responsibility of a professional to provide the 
service at a therapist's facility. Some of the States which were 
previously allowing bay/box/picture windows have discontinued this 
practice in accordance with the efforts to contain costs, an action 
which we support.
30. Section 1944.215(a)(11)
    Comment: One respondent supported the inclusion of individual 
patios for the elderly as a means for increasing socialization. Two 
respondents supported washer and dryer hookups for all types of units.
    FmHA response: FmHA views the community room as instrumental in 
encouraging elderly tenant socialization. In a recent survey conducted 
by the National Association of Home Builders, tenants were asked to 
list amenities in order of their desirability. This survey showed that 
balconies were ranked by the tenants at number 15 out of a list of 16 
amenities. We place individual patios in the same category with 
balconies. See discussion of washer and dryer hookups under 
Sec. 1944.212(g), above.
31. Section 1944.215(a)(12)
    Comment: One respondent voiced support for allowing outdoor 
recreation for elderly projects for those occasions where there are 
minor children in the unit and where grandchildren come to visit. There 
was support expressed for the allowance for garbage disposals and 
community rooms for family projects.
    FmHA response: Playground equipment would either stand idle in the 
case where there were no minors living with the elderly or would 
attract children from outside the project. The noise generated as a 
result of playgrounds would not be viewed as a welcome addition by some 
of the elderly residents who enjoy peaceful surroundings. FmHA response 
to community rooms for family projects and garbage disposals has 
already been discussed under Sec. 1944.215(a)(10) above.
32. Section 1944.215(a)(13)
    Comment: Several respondents objected to the number of parking 
spaces for elderly since more persons now keep their cars for a longer 
period of time, particularly since those persons reside in rural areas 
with no other means of transportation. One respondent recommended that 
spaces for visitors and health care workers not be included in the 
calculation. One respondent suggested that this limit be recommended 
and not mandated. One respondent recommended the limit be set at 1.5 to 
2 for family and .5 to 1.25 for elderly; another respondent recommended 
.75 to 1.25 for elderly. One respondent supported this section.
    FmHA response: A 1990 congregate housing study revealed that only 
21 percent of congregate tenants owned cars. The proposed allowance for 
congregate parking spaces is based on that percentage. In order to 
accommodate the additional cars owned by persons in elderly projects, 
we have changed the language of this section to allow for additional 
spaces for visitors and staff.
33. Section 1944.215(a)(14)
    Comment: A number of respondents objected to establishing a range 
of acceptable allowances for earthwork. A couple of respondents 
mistakenly interpreted this section to mean that the allowance cover 
the combination of landscaping and earthwork.
    FmHA response: FmHA's cost tracking system will allow us to capture 
landscaping and earthwork costs; therefore, the section has been 
amended to delete the requirement that ranges be established.
34. Section 1944.215(a)(15)
    Comment: One respondent recommended that congregate projects where 
an expanded meal service is designed to provide meals to all of the 
community's elderly citizen be exempted from the limitations of the 
Manual of Acceptable Practices (MAP). The same respondent pointed out 
that the MAP is a supplement to an obsolete minimum property standards. 
Another respondent pointed out that the MAP is not available in any 
FmHA office. One respondent agreed with this section.
    FmHA response: The MAP is no longer in print. Guidance pertaining 
to the size of these facilities can be found in Guide 2 of FmHA 
Instruction 1924-A. This section has been changed to reflect the proper 
reference.
35. Section 1944.215(b)(1)
    Comment: Several respondents objected to this way of measuring 
square footages. Two others objected to restricting congregate units to 
110 percent of the minimum square footages since this dimension may not 
allow sufficient square footages to meet the requirements of the 
Americans with Disabilities Act. One respondent voiced the opinion that 
setting the square foot limits will lead to a drop to the minimum 
footages and adversely impact the rentability. One respondent 
recommended a lower maximum square footage. One respondent recommended 
eliminating the reference to ``related facilities'' since their 
inclusion will distort the square footage of ``living area.''
    FmHA response: The methodology described in this section for 
calculating living area is consistent with common industry practices. 
Congregate living units are not affected by the Americans with 
Disabilities Act. We do not understand the concern that setting the 
square foot limit will lead to a drop to the minimum footages since 
these ranges have been in existence for some time and have not resulted 
in an automatic drop in square feet. We see no reason to lower the 
maximum square footage since the size of the unit can be controlled 
within the allowable ranges. The section has been changed to eliminate 
``related facilities'' from being included in the computation of living 
area.
36. Section 1944.215(e)
    Two comments were received and the respondents supported this 
section.
37. Section 1944.215(w)(3)
    Comment: A number of respondents objected to FmHA's requiring the 
applicant to reveal the percentage of tax credits it will seek. Several 
persons appeared to misinterpret the intent of the section. A few of 
the respondents felt that FmHA is attempting to make the determination 
of the number of tax credit units the project will receive. One 
respondent suggested that the section be amended to state that the 
``market study'' will be subject to further examination and not the 
preapplication itself. One respondent points out that if the project is 
requesting rental assistance, the affordability of basic rent is 
irrelevant. One person recommended that the word ``percentage'' to 
changed to ``number'' to avoid confusion. Several persons supported 
this section.
    FmHA response: FmHA regulations require that the Agency determine 
whether a proposed project is feasible. In order for a project to be 
feasible, there must be persons of sufficient incomes to support the 
expenses and to amortize the loan. The market for 515 projects depends 
on the existence of persons with a lower level of incomes in those 
cases where tax credits are awarded to the borrower. Many market 
analysts are still determining need based on incomes up to the moderate 
level. This becomes an issue when there is not sufficient rent subsidy 
for all units. In order to make a proper analysis of feasibility, we 
must determine the level of incomes which will be required to support 
the project. Even if the applicant requests 100 percent rental 
assistance and there is sufficient subsidy to cover all of the units, 
FmHA is not absolved of its responsibility of examining feasibility. 
FmHA feels that it is imperative that we are aware of the number of tax 
credit units anticipated so that the appropriate level of incomes can 
be studied. In no way does FmHA intend to become involved in the 
determination of the number of tax credits assigned to a project by the 
State Agencies. We will, however, provide information to the State 
Agencies as to the amount of financial assistance granted to the 
borrower by FmHA. The word ``percentage'' has been changed to 
``amount'' and the words ``percentage of units targeted for tax credit 
eligible persons'' have been added.
38. Section 1944.231(a)(2)
    Comment: A number of respondents supported this section with the 
stipulation that no other preapplication be authorized until the second 
market study has been completed and a determination made on the 
original preapplication. Two respondents pointed out that the 45-day 
period in which to respond to the applicant is not sufficient to 
accomplish the necessary processing.
    FmHA response: FmHA agrees that the preapplication hold its 
position in the ranking and has amended the section to state that no 
other preapplication will move ahead of the preapplication in question 
until the feasibility issue has been resolved. The contracts will be 
similar to those used by the Agency in obtaining appraisals in that the 
State will let one contract under which the market studies will be 
prepared by one or more market analysts. This will eliminate the need 
for contracting for each individual study, thus saving processing time.
39. Section 1944.235(a)(1)
    Comment: Two respondents suggested that closing instructions be 
furnished to the borrower within a certain timeframe.
    FmHA response: The issuance of the closing instructions involves 
coordination and input from another Government Agency. While FmHA may 
request more expeditious issuance of the closing instructions, it has 
no control over when the instructions will be furnished. Additionally, 
we have no way of knowing how the process is impacted by that Agency's 
workload.
40. Section 1944.235(a)(2)
    Comment: One respondent supported this section. Another respondent 
stated that this section does not agree with the earlier requirement 
concerning what amount needs to be furnished to cover the initial O&M 
amount discussed in Sec. 1944.211(a)(7)(i).
    FmHA response: This issue was discussed under 
Sec. 1944.211(a)(7)(i), above.
41. Section 1944.235(b)(3)
    Comment: One respondent suggested that an appeal process be 
included for co-general partners. One respondent suggested that another 
provision be added to allow transfer of an obligation when the 
applicant is unable to continue for legitimate reasons and the 
transferee is eligible for 515 assistance. Another respondent suggested 
consideration be given to who is responsible for the default so that a 
co-general partner who is innocent of the default will not be penalized 
by being denied access to the program for 5 years.
    FmHA response: We interpret the first and last respondent comments 
to pertain to the same concern. FmHA does not agree that a co-general 
partner be exempt from these provisions since the loan was made to the 
entity and it is up to the entity to maintain its financial integrity. 
The regulations already contain provisions for handling cases where the 
entity chooses to transfer an obligation without monetary default. 
There would be no penalty in that case.
42. Section 1944.235(c)(1)
    Comment: One respondent suggests that the language be changed to 
allow interim lenders who are now making loans to only FmHA-financed 
projects. Another suggested that the language be changed to state 
``other than identity of interest companies.'' Another respondent felt 
that the record of providing financing to non-FmHA projects be on a 
national basis and not limited to the State in which a particular loan 
is made. A respondent suggested that the language be changed to state 
the lender be ``authorized'' to do business in a State since not all 
States require the lender to be licensed. Two respondents suggested 
that FmHA provide the interim financing to eliminate the expense 
connected with outside interim financing. Two other respondents voiced 
their objection to this section. Two respondents supported this 
section.
    FmHA response: FmHA feels strongly that the borrower not provide 
its own interim financing. The interim lender is responsible for 
inspecting each stage of construction. If borrowers are allowed to 
provide their own interim financing they, in essence, would also be 
allowed to inspect their own construction. FmHA feels that inspections 
by arms-length third parties will provide a more objective assessment 
of construction standards and quality. The language has been changed to 
state that the lender be ``authorized'' to do business in a State 
rather than ``licensed.'' As long as interim financing can be secured 
at reasonable rates, fees, and terms, FmHA does not feel that the 
wholesale use of Government funds for interim financing is in keeping 
with the intent that local lenders be given the opportunity of 
furnishing the interim financing.
43. Section 1944.236
    Comment: Two respondents objected to nonprofit borrowers being able 
to use an attorney who is a member of their organization while limited 
profit borrowers are prohibited from doing the same.
    FmHA response: The only change being made to this section is to 
correspond to a recent wording change in FmHA's closing regulation. The 
use of member attorneys by nonprofit groups has been allowed by the 
regulation for some time. FmHA does not consider the relationship 
between a nonprofit borrower and its attorney in any way resembles the 
relationship between a profit-motivated borrower and its attorney. The 
nonprofit attorney has no financial interest in the nonprofit whereas 
the reverse can be true of the attorney who is a member of the limited 
profit.
44. Section 1944.237(a)
    Comment: One respondent suggested that this section be amended to 
make clear that subsequent loans to existing borrowers for 
rehabilitation do not have to go through the preapplication process. 
Another respondent felt that this will adversely affect developers who 
acquired land for a future second phase. Another respondent recommended 
that this section show what types of paperwork are needed for a 
subsequent loan or that the information be contained in an exhibit to 
the regulation. Two respondents expressed their opinion that the 
language which states that subsequent loans made on or after December 
15, 1989, cannot be prepaid is contrary to prior interpretations by the 
National Office. Another person suggested that this section be revised 
to permit the addition of office, laundry, maintenance, or other 
community space not be subject to rating and ranking. One respondent 
agreed with this section.
    FmHA response: This section states that subsequent loans to develop 
additional units must be rated and ranked. All other subsequent loans 
which do not fall within this definition are excluded, including 
rehabilitation of existing FmHA-financed units. It was always FmHA's 
intention that subsequent loans to develop additional units be subject 
to the rating system; this section merely clarifies that intention. 
FmHA agrees that some guidance be added to the regulation which better 
defines what types of paperwork are required for subsequent loans. The 
types of paperwork needed for subsequent loans has been added to the 
regulation as Exhibit A-14. Prepayment is covered by proposed changes 
now being incorporated in FmHA regulations. Office, laundry, 
maintenance, and other community space facilities are not considered 
living units and do not fall under this definition.
45. Exhibit A

Paragraph IV.B.6

    Comment: Two respondents expressed their opinion that no new AD-622 
be issued until the market question is resolved.
    FmHA response: This was discussed under section 1944.231(a) above.
46. Exhibit A-2
    Comment: One respondent felt that a new column ``housing 
condition'' be added to this exhibit.
    FmHA response: The respondent did not make known whether the 
reference to housing condition refers to the overall condition or to 
the interior condition of the units. If the latter, we have 
deliberately not required this type of information since it would be 
almost impossible for a market analyst to inspect the inside of the 
units. In the case of the overall exterior condition of the property, 
FmHA feels this analysis is subject to the personal feelings of the 
analyst and would not be based on any uniform means for ranking the 
physical condition. FmHA does require the analyst to give an opinion as 
to the upkeep of the existing stock in accordance with Exhibit A-8, 
``Outline of Professional Market Study.''
47. Exhibit A-7

Paragraph I.A

    Comment: There were many objections raised to this section that 
requires an audited financial statement. It was pointed out that, even 
if individual financial statements could be audited, the cost for 
providing the original and updates during the processing period would 
be prohibitive. These same individuals objected to providing a copy of 
their prior year income tax return because it is deemed an invasion of 
privacy. One respondent pointed out the hardship this would create for 
nonprofit applicants and proposed that they be able to provide their 
most recent audited statement. One respondent supported this section 
but suggested that ``current'' be defined as the end of the company's 
last fiscal year and that updates be unaudited. One respondent 
suggested that instead of requiring audited financial statements, a 
good review of financial statements by FmHA personnel would ensure 
financial security. Several persons pointed out the fact that most 
applicants are newly established organizations which have no financial 
record to audit. One respondent representing a Certified Public 
Accounting firm stated that it is often impracticable to conduct an 
examination of personal financial records in accordance with generally 
accepted accounting principles and to express an unqualified opinion. 
That respondent recommended the section be changed to require that the 
personal financial statements either be compiled or reviewed and stated 
that a detailed and complete underwriting of creditworthiness can be 
performed on compiled or reviewed personal financial statements that 
are comprehensively prepared. Two respondents supported this section.
    FmHA response: In light of the difficulty in obtaining audited 
financial statements of individuals, FmHA will continue with the 
requirements currently in existence and has eliminated the word 
``audited'' from this section. The Agency also feels that a proper 
analysis of a financial statement will provide a better understanding 
of an applicant's creditworthiness than would an individual's income 
tax statement. FmHA maintains the position that a financial statement 
not be more than 6 months old when the preapplication is filed.
48. Exhibit A-7

Paragraph I.H

    Respondents agreed with this section.
49. Exhibit A-7

Paragraph II.A

    Comment: One respondent recommended that FmHA establish a 
percentage of elderly homeowners that could be considered as potential 
tenants. Two respondents disagreed with the use of a checklist in 
evaluating market studies. A few respondents disagreed with limiting 
the area of consideration to 20 percent of the substandard rental 
units. Two respondents objected to the use of professional market 
studies in the analysis of need and suggested that personal contact 
with possible tenants, talking with other apartment owners, or 
conducting a newspaper questionnaire would provide a more credible 
means for determining need. One respondent suggested that we include a 
definition of ``substandard units.'' Also, that respondent pointed out 
that the same persons who reside in ``overcrowded'' units are being 
doublecounted, first from the substandard category and second from the 
new households category. One respondent agreed with this section.
    FmHA response: FmHA does not agree that elderly homeowners should 
be considered in the need for units. That is not to say these elderly 
homeowners cannot live in the FmHA-financed unit. We do not feel that 
the general market can absorb the sale of multiple homes at one time. 
Exhibit A-8 does state that if the economic conditions reflect normal 
selling times for homes in the market area, then elderly homeowners may 
be considered as a secondary market. FmHA has had in use a checklist 
for analyzing market studies for some time; this regulation now 
requires its use to enhance internal control over administration of the 
program. The purpose of the checklist is to enable the reviewer to 
determine if all segments of Exhibit A-8 have been addressed by the 
study.
    Market demand and feasibility is created by several factors. One of 
those factors is the demand created by persons who are living in 
substandard units and seeking decent, safe and sanitary housing which 
can be financed by FmHA. Currently, there is no limit on the percentage 
of substandard units which an analyst can project in determining market 
demand. For example, if there are 100 units of substandard housing in a 
given market, analysts can and have stated that 80, or any other 
arbitrary, percentage of the families living in these units create a 
portion of the demand. We have found that the percentage of units 
projected as a result of substandard housing varies significantly from 
study to study. In addition, without any boundaries, it provides the 
market analyst with a contingency to justify demand. The 20 percent 
limitation was offered based upon previous experience with market 
analysis. Without a threshold, FmHA is defenseless in challenging a 
professional market analyst. It is reasonable to set a limit since 
there is no objective methodology in which to actually determine how 
many people residing in substandard units will move to a newly 
completed Section 515 complex. The Agency will, however, allow a higher 
number if the analyst can clearly document that the occupants of more 
than 20 percent of the occupied substandard rental units are willing 
and able to relocate to the proposed housing. The documentation will be 
in the form of signed survey sheets prepared expressly to capture such 
information.
    The use of market studies does not prohibit anyone from doing more 
to assess the market, such as making local contacts. Placing a 
questionnaire in a newspaper does not ensure the return of any 
responses. A definition of substandard has been added.
    FmHA feels it necessary to standardize the way need is calculated 
in order to provide some uniformity in market studies. The revised 
Exhibit A-8 outlines the sources of demand which will be accepted by 
the Agency. There was a discrepancy between this section and the 
Exhibit A-8 language in delineating sources of need. This section of 
the regulation has been changed to agree with the language of Exhibit 
A-8.

Paragraph II.F

    Comment: One respondent suggested that the tax credit income 
information be provided with the application and not with the 
preapplication.
    FmHA response: Feasibility must be determined during the 
preapplication stage and the ranges of local incomes must be 
established at that time. For this reason, the Agency cannot change 
this requirement. Other discussions concerning tax credit incomes is 
found under Sec. 1944.215(w)(3).
50. Exhibit A-7

Paragraph III.C

    Comment: One respondent suggested adding a provision that the 
option to buy be with the current owner of public record.
    FmHA response: We agree with this suggestion and have added that 
provision.
51. Exhibit A-7

Paragraph IV.F

    Comment: One respondent objected to applicants who publicly bid 
their projects having to submit a Form FmHA 1924-13. One respondent 
felt that requesting this much detail information at the preapplication 
stage would not prove useful since cost estimates change markedly 
between preapplication and application. One respondent supported this 
section.
    FmHA response: FmHA's new cost tracking system will track the trade 
item costs of each project. The Form FmHA 1924-13 provides a breakdown 
of trade item costs which will readily facilitate the use of the cost 
tracking system. Otherwise, the value of the tracking system will be 
diminished, thus not allowing the Agency to establish cost data 
comparisons. Persons submitting bids must have prepared extensive cost 
estimates in preparing the bid. Therefore, we do not feel this will 
cause an undue burden on the contractor.
52. Exhibit A-8
    Comment: One respondent suggested that a definition of substandard 
be included. One respondent asked if FmHA intends to prepare and 
distribute special tabulations of substandard units by its definition, 
by occupancy, tenure, income, and household size. Several respondents 
expressed objection to FmHA not considering elderly homeowners as a 
basis of need. Several respondents objected to the 20 percent ceiling 
on substandard units which FmHA will accept in the determination of 
need. One respondent raised the question of who is responsible for 
determining if the analyst is qualified and what the qualifications are 
for preparing a study. That person also wanted to know if the study is 
incomplete, is the preapplication determined incomplete and returned to 
the applicant. Two respondents felt that requiring the market analyst 
to make an on-site visit was a significant improvement in this exhibit. 
One respondent suggested that the exhibit be used as a guide only and 
not mandated. One respondent asked if FmHA intended to exclude 
rentoverburden households from rentup demand estimates. That respondent 
also expressed an opinion that the listing of small businesses in the 
Site section of the exhibit would be construed to mean those businesses 
must be available in order for a community to be considered eligible 
for FmHA financing. Other comments and suggestions offered on the 
technical content of the exhibit are too numerous to list here.
    FmHA response: A definition for substandard has been included. HUD 
furnished FmHA with information pertaining to occupancy in substandard 
units based on the 1980 census. That information was disseminated to 
our field staff for distribution to market analysts. We are in the 
process of coordinating with HUD to obtain this same data when it 
becomes available. (See discussion of elderly homeowners under Exhibit 
A-7, Paragraph II.A. and a discussion of substandard housing under 
Exhibit A-7, Paragraph II.A). The qualifications of a market analyst 
and the responsibility for determining whether an analyst is qualified 
are iterated in Exhibit A-7 of this instruction. If a market study is 
incomplete, the applicant may furnish additional information to 
complement the market study without the necessity of returning the 
entire preapplication. This will inevitably delay the processing of the 
preapplication. The requirement that a market analyst visit the site of 
the proposed project was not introduced with this revision; it has 
always been a requirement. The purpose of the exhibit is to require 
enough information on which a feasibility decision can be based and to 
establish uniformity in the content of studies. Prior to FmHA issuing 
the exhibit, the market studies varied greatly and all did not contain 
the most basic types of information. We have seen a marked improvement 
in the studies because of the issuance of the exhibit. While FmHA 
originally allowed applicants to consider the exhibit as a guideline, 
we did not feel it prudent to continue this practice. The exhibit is, 
therefore, required in order for the study to be acceptable to the 
Agency; market studies which do not contain Exhibit A-8 requirements 
will not be acceptable. We understand that the HUD information on 
rentoverburdened households is not yet available. In the interim, 
language has been added to the exhibit which invites the analyst to 
include this type of information where available. While this exhibit is 
not the proper vehicle for establishing policies concerning required 
community services and facilities, the Site section has been reworded 
to state that the businesses listed are an example of the types of 
business which may be located in the community.
    Many of the proposed changes are based on comments and 
recommendations submitted from market analysts over the past two years. 
Market analysts have expressed differing opinions concerning the 
content of this exhibit. We have considered all of these differing 
opinions and have amended the exhibit to include what we consider a 
rational and understandable basis for a market study. We have attempted 
to correct the original exhibit requirements where it lacked sufficient 
statistics to make a determination for elderly and congregate projects. 
Other changes made to the exhibit will standardize the types of 
information market studies will contain and provide the uniformity 
heretofore missing. We have considered all comments and the exhibit now 
reflects those changes which FmHA has determined appropriate for 
inclusion.
53. Exhibit A-9

Paragraph 2

    Comment: One respondent suggested a rewrite of this section to 
include other items of construction.
    FmHA response: This section has been reworded to further define 
what types of information on related costs must be submitted in 
addition the Form FmHA 1924-13.

Paragraph 5

    Comment: A few respondents recommended that the market information 
be updated after 12 months rather than requiring a new study.
    FmHA response: FmHA feels this is reasonable and has changed the 
wording to reflect an update rather than a new study.
    54. Exhibit A-10 is Amended to Include Language Implementing 
Section 515(x)(2) of the Housing Act of 1949, as Amended, to Provide 
for Cooperation between FmHA and State Agencies in Developing a 
Comprehensive Housing Affordability Strategy (CHAS)
    Other comments: Other comments were received which were general in 
nature and did not pertain to any specific issues. These comments have 
not been addressed by FmHA.

List of Subjects

7 CFR Part 1924

    Agriculture, Construction management, Construction and repair, 
Energy conservation, Housing, Loan programs--Agriculture, Low and 
moderate income housing.

7 CFR Part 1930

    Accounting, Administrative practice and procedure, Grant programs--
Housing and community development, Loan programs--Housing and community 
development, Low and moderate income housing--Rental, Reporting 
requirements.

7 CFR Part 1944

    Administrative practice and procedure, Aged, Handicapped, Loan 
programs--Housing and community development, Low- and moderate-income 
housing--Rental, Mortgages, Nonprofit organizations, Rent subsidies, 
Rural housing.

    Accordingly, parts 1924, 1930, and 1944, chapter XVIII, title 7, 
Code of Federal Regulations are amended as follows:

PART 1924--CONSTRUCTION AND REPAIR

    1. The authority citation for part 1924 continues to read as 
follows:

    Authority: 7 U.S.C. 1989; 42 U.S.C. 1480; 5 U.S.C. 301; 7 CFR 
2.23; 7 CFR 2.70.

Subpart A--Planning and Performing Construction and Other 
Development

    2. Section 1924.4 is amended by redesignating paragraphs (i)(4) 
through (i)(7) as (i)(5) through (i)(8), respectively, and by adding 
paragraphs (i)(4) and (i)(9) to read as follows:


Sec. 1924.4  Definitions.

* * * * *
    (i) * * *
    (4) Between the spouse, significant other, relatives, and step-
relatives of the principal owners of the party of the first part and 
its management, such as Grandmother, Aunt, Daughter, Granddaughter, 
Grandfather, Uncle, Son, Grandson, Mother, Sister, Niece, Cousin, 
Father, Brother, Nephew;
* * * * *
    (9) An identity of interest will also exist when another party can 
significantly influence the management or operating policies of the 
transacting parties or if it has an ownership interest in one of the 
transacting parties and can significantly influence the other to an 
extent that one or more of the transacting parties might be prevented 
from fully pursuing its own separate interests.
* * * * *
    3. Section 1924.13 is amended by revising paragraphs (a)(3), 
(e)(1)(iii)(B)(2), (e)(1)(iv), (e)(1)(v), (e)(1)(vii)(B)(1), 
(e)(2)(i)(B), (e)(2)(i)(G), (e)(2)(i)(H), (e)(2)(ii)(C), 
(e)(2)(iii)(A), (e)(2)(iv), (e)(2)(v), and (e)(2)(viii) to read as 
follows:


Sec. 1924.13  Supplemental requirements for more complex construction.

* * * * *
    (a) * * *
    (3) Architectural fees. Fees for architectural services shall not 
exceed the fee ordinarily charged by the profession for similar work 
when FmHA financing is not involved. The fee should cover only the 
architectural services rendered by the architect. The reduction or 
elimination of any services described in paragraph (a)(5) of this 
section shall be directly reflected in the fee. Fees for special 
services rendered by the architects, such as the packaging of the loan 
application or additional nonarchitectural services, will not be 
authorized to be paid with loan funds.
* * * * *
    (e) * * *
    (1) * * *
    (iii) * * *
    (B) * * *
    (2) A current, dated and signed financial statement of the 
contractor's operations indicating the payment status of accounts and 
any contingent liabilities that may exist. FmHA personnel will be 
responsible for analyzing the financial statement as to the sufficiency 
of the contractor's financial capability to carry out construction. The 
financial strength must demonstrate the ability of the contractor to 
pay all bills prior to receiving periodic draws of funds from the 
lender.
* * * * *
    (iv) Contract cost breakdown. In any case where the loan approval 
official feels it appropriate, and prior to the award or approval of 
any contract in which there is an identity of interest as defined in 
Sec. 1924.4 (i) of this subpart, the contractor and any subcontractor, 
material supplier or equipment lessor sharing an identity of interest 
must provide the applicant and FmHA with a trade-item cost breakdown of 
the proposed contract amount for evaluation. The cost of any surety as 
required by Sec. 1944.222 (h) and (i) of subpart E of part 1944 of this 
chapter and Sec. 1924.6 (a)(3) of this subpart, or cost certification 
as required by paragraph (e)(1)(v) of this section, will be included in 
the proposed contract amount and shown under General Requirements on 
Form FmHA 1924-13, which is available in all FmHA offices. FmHA 
personnel will be responsible for reviewing the estimates on Form FmHA 
1924-13 to determine if the dollar amounts total correctly, to assure 
that costs are categorized under their appropriate columns, and to 
confirm that the estimated costs for all line items are reasonable and 
customary for the State.
    (v) Cost certification. Whenever the State Director determines it 
appropriate, and in all situations where there is an identity of 
interest as defined in Sec. 1924.4 (i) of this subpart, the borrower, 
contractor and any subcontractor, material supplier, or equipment 
lessor having an identity of interest must each provide certification 
using Form FmHA 1924-13 as to the actual cost of the work performed in 
connection with the construction contract. The construction costs, as 
reported on Form FmHA 1924-13, must also be audited, in accordance with 
Government Auditing Standards, by a CPA, or LPA licensed on or before 
December 31, 1970. In addition, certain agreed upon procedures 
(available in any FmHA office) will be performed in accordance with 
Attestation Standards. In some cases, FmHA will contract directly with 
a CPA or LPA for the cost certification. In that event, documentation 
necessary to have the costs of construction certified by an FmHA 
contractor that they were the actual costs of the work performed, as 
reported on Form FmHA 1924-13, will be provided. Funds which were 
included in the loan for cost certification and which are ultimately 
not needed because FmHA contracts for the cost certification will be 
returned on the loan. FmHA personnel will utilize Exhibit M of this 
subpart (available in any FmHA office) and Form FmHA 1924-26, ``Cost 
Certification Worksheet,'' to assist in the evaluation of the cost 
certification process.
    (A) Prior to the start of construction, the borrower, contractor 
and any subcontractor, material supplier, or equipment lessor sharing 
an identity of interest must submit, to the CPA or LPA, the accounting 
system that the borrower, contractor, subcontractor, material supplier 
or equipment lessor and/or the CPA or LPA proposes to set up and use in 
maintaining a running record of the actual cost. In order to be 
acceptable, the borrower must provide a written assertion that it has 
an accounting system that is suitably designed to provide for a trade-
item basis comparison of the actual cost as compared to the estimated 
cost submitted on Form FmHA 1924-13. Costs pertaining to a specific 
line item will be set up in the accounting system for that particular 
account. For instance, only costs of materials, supplies, equipment, 
and labor associated with concrete will be shown in the concrete 
account. The accounting system must also restrict costs to those 
pertaining to a specific project so that costs from multiple projects 
will not be co-mingled. The independent CPA or LPA shall report on the 
borrower's assertion in accordance with the Standards for Attestation 
Engagements of the American Institute of Certified Public Accountants 
(AICPA). The borrower's and the CPA or LPA's reports on the accounting 
system shall be provided to FmHA by the borrower.
    (B) Prior to final payment to anyone required to cost certify, a 
trade-item breakdown showing the actual cost compared to the estimated 
cost must be provided to the owner and FmHA. Form FmHA 1924-13 is the 
form of comparative breakdown that must be used, and contains the 
certifications required of the applicant and contractor prior to final 
payment. The amounts for builder's general overhead, builder's profit, 
and general requirements, respectively, shall not exceed the amounts 
represented on the estimate of cost breakdown provided in accordance 
with paragraph (e)(1)(iv) of this section for any contractor, 
subcontractor, material supplier, or equipment lessor having or sharing 
an identity of interest with the borrower. The amounts for general 
overhead, builder's profit, and general requirements must be 
established prior to FmHA approving the construction contract and will 
not be changed during the course of construction. This applies to all 
contractors, subcontractors, material suppliers, or equipment lessors 
having or sharing an identity of interest with the applicant. Contract 
change orders will be processed to adjust the contract amount downward 
prior to the final payment to the contractor, if necessary, to assure 
that the amounts shown in the certificate of actual costs do not exceed 
the amounts represented in the contract cost breakdown. Reduction in 
the builder's profit, and general overhead if needed, will 
counterbalance any increase reflected in the contract costs. Any funds 
remaining as a result of hard cost savings will be applied to the 
account as an extra payment or used for eligible loan purposes approved 
by FmHA as long as the improvements are genuinely needed and will 
enhance marketability of the project. All increases or decreases of 15 
percent or more in line item costs will require documentation as to the 
reason for the increases and/or decreases. The State Director may 
require documentation for increases and/or decreases of less than 15 
percent, if he/she determines it necessary. This information will be 
required with the cost certification.
    (C) The CPA or LPA audit, performed in accordance with Government 
Auditing Standards, will include such tests of the accounting records 
and such other auditing procedures of the borrower and the contractor 
(and any subcontractor, material supplier or equipment lessor sharing 
an identity of interest) concerning the work performed, services 
rendered, and materials supplied in accordance with the construction 
contract he/she considers necessary to express an opinion on the 
construction costs as reported on Form FmHA 1924-13. The CPA or LPA 
shall also perform the additional agreed upon procedures specified by 
FmHA (available in any FmHA office), performed in accordance with 
Attestation Standards, for the applicant and the contractor (and any 
subcontractor, material supplier, or equipment lessor sharing an 
identity of interest) concerning the work performed, services rendered, 
and materials supplied in accordance with the construction contract.
    (D) Upon completion of construction and prior to final payment, the 
CPA or LPA will provide an opinion concerning whether the construction 
costs, as reported on Form FmHA 1924-13, present fairly the costs of 
construction in conformity with eligible construction costs as 
prescribed in FmHA regulations.
    (E) In some cases, cost certification will be obtained by FmHA 
through direct contract with the CPA or LPA. The borrower and his/her 
CPA or LPA will cooperate fully with the contract CPA or LPA by 
providing all documentation necessary to conduct the certification. 
FmHA reserves the right to determine, upon receipt of the certified 
Form FmHA 1924-13 and the auditor's report, whether they are 
satisfactory to FmHA. If not satisfactory to FmHA, the borrower will be 
responsible for providing additional information.
    (F) There will exist no business relationship between the CPA or 
LPA and the borrower except for the performance of the examination of 
the cost certification, accounting systems work, and tax preparation. 
Any CPA or LPA who acts as the borrower's accountant (performing manual 
or automated bookkeeping services or maintains the official accounting 
records) will not be the same CPA or LPA who cost certifies the 
project.
    (G) Forms FmHA 1944-30, ``Identity of Interest (IOI) Disclosure 
Certificate'' and FmHA 1944-31, ``Identity of Interest (IOI) 
Qualification Form,'' provide written notification to the borrower that 
willful and intentional falsification of cost certification documents 
will result in debarment of all violators in accordance with the 
provisions of FmHA Instruction 1940-M (available in any FmHA office). 
These forms require the disclosure of all identities of interest 
associated with project construction, certify the entity's ability to 
provide the contracted service, and cite the penalties for failure to 
disclose or falsify such certification. Each applicant/borrower will be 
required to complete and sign the forms (available in any FmHA office).
    (H) Subcontracting development work.
    (1) Contractors will not be allowed to obtain a profit and overhead 
unless they are performing actual construction. ``Actual construction'' 
means ``work'' as defined in American Institute of Architects (AIA) 
documents: ``* * * labor, materials, equipment, and services provided 
by the contractor to fulfill the contractor's obligations.'' Under this 
definition, contractors who choose to subcontract out construction of 
the project to another contractor will not obtain a builder's fee 
(general overhead and profit) when:
    (i) More than 50 percent of the contract sum in the construction 
contract is subcontracted to one subcontractor, material supplier, or 
equipment lessor, and/or
    (ii) Seventy-five percent or more with three or fewer 
subcontractors, material suppliers and/or equipment lessors.
    (2) Note: If two or more subcontractors have common ownership, they 
are considered as one subcontractor.
    (3) How to apply rule:
    (i) The 50 percent rule will apply when division of the amount of 
the largest subcontract by the contract sum of the construction 
contract results in more than 50 percent.
    (ii) The 75 percent rule will apply when division of the sum of the 
amounts of the three largest subcontracts by the contract sum of the 
construction contract results in 75 percent or more.
    (I) Qualified contracting entities. Contractors, subcontractors, 
material suppliers, and any other individual or organization sharing an 
identity of interest and providing materials or services for the 
project must certify that it is a viable, ongoing trade or business 
qualified and properly licensed to undertake the work for which it 
intends to contract. Form FmHA 1944-31 will be prepared and executed by 
the contracting entities. The form provides notification to the 
entities of the penalty, under law, for erroneously certifying to the 
statements contained therein. Debarment actions will be instituted 
against entities who fail to disclose an identity of interest in 
accordance with the provisions of FmHA Instruction 1940-M (available in 
any FmHA office).
* * * * *
    (vii) * * *
    (B) * * *
    (1) If, after a full review of the case documents by the 
appropriate members of the State Office staff, the State Director 
determines that the requirements have been met and the costs are 
reasonable, an exception to competitive bidding may be granted. Written 
documentation of the State Office review results will be placed in the 
application file.
* * * * *
    (2) * * *
    (i) * * *
    (B) Dated and signed financial statements on the owner-builder's 
operation (including balance sheets and statements of income and 
expense) from current and prior years indicating the payment status of 
the owner-builder's accounts and any contingent liabilities that may 
exist. FmHA personnel will be responsible for analyzing the financial 
statement as to the sufficiency of the owner-builder's financial 
capability to carry out construction. The financial strength must 
demonstrate the ability of the owner-builder to pay all bills prior to 
receiving periodic draws of funds from the lender.
* * * * *
    (G) A current, dated, and signed trade-item cost breakdown of the 
estimated total development cost of the project which has been prepared 
by the applicant/owner-builder. Form FmHA 1924-13 will be used for this 
purpose. If cost certification services are required by FmHA, the cost 
of such services may be included in the total development cost of the 
project. Any subcontractor, material supplier, or equipment lessor 
sharing an identity of interest with the applicant/owner-builder as 
defined in Sec. 1924.4(i) of this subpart must also provide a trade-
item cost breakdown of the proposed amount.
    (H) Prior to the start of construction, the owner-builder and any 
subcontractor, material supplier, or equipment lessor sharing an 
identity of interest must submit, to the CPA or LPA, the accounting 
system that the owner-builder, subcontractor, material supplier or 
equipment lessor and/or the CPA or LPA proposes to set up and use in 
maintaining a running record of the actual cost. In order to be 
acceptable, the owner-builder must provide a written assertion that it 
has an accounting system that is suitably designed to provide for a 
trade-item basis comparison of the actual cost as compared to the 
estimated cost submitted on Form FmHA 1924-13. Costs pertaining to a 
specific line item will be set up in the accounting system for that 
particular account. For instance, only costs of materials, supplies, 
equipment, and labor associated with concrete will be shown in the 
concrete account. The accounting system must also restrict costs to 
those pertaining to a specific project so that costs from multiple 
projects will not be co-mingled. The independent CPA or LPA shall 
report on the owner-builder's assertion in accordance with the 
Standards for Attestation Engagements of the AICPA. The owner-builder's 
and the CPA or LPA's reports on the accounting system shall be provided 
to FmHA by the owner-builder.
* * * * *
    (ii) * * *
    (C) The total development cost of the project does not exceed that 
which is typical for similar type projects in the area. The total 
development cost recognized by FmHA for each individual case will be 
determined by the MFH Coordinator with the advice of the State 
Architect.
* * * * *
    (iii) * * *
    (A) If, after a full review of the case documents by the 
appropriate members of the State Office staff, the State Director 
determines that the requirements have been met and the construction 
cost is reasonable, an exception to competitive bidding may be granted. 
Written documentation of the State Office review results will be placed 
in the application file.
* * * * *
    (iv) The development cost of the project may include a typical 
allowance for general overhead, general requirements and a builder's 
profit. These amounts may be determined by local investigation and also 
from HUD data for the area. The applicant/owner-builder and any 
subcontractors, material suppliers and equipment lessors having or 
sharing an identity of interest with the applicant/owner-builder may 
not be permitted a builder's profit, general overhead, and general 
requirements which exceed the amounts represented on their cost 
breakdown.
    (v) Under no circumstances will loan funds be used to pay the 
owner/builder or its stockholders, members, directors or officers, 
directly or indirectly, any profits from the construction of the 
project except a typical builder's fee for performing the services that 
would normally be performed by a general contractor under the contract 
method of construction. Discounts and rebates given the owner-builder 
in advance must be deducted before the invoices are paid. If discounts 
or rebates are given after the invoices are paid, the funds must be 
returned to the supervised bank account or applied on the interim 
construction loan, as appropriate. Under no circumstances will the 
dollar amount be placed in the reserve account.
* * * * *
    (viii) The applicant/owner-builder and any subcontractor, material 
supplier, or equipment lessor sharing an identity of interest as 
defined in Sec. 1924.4(i) of this subpart must each provide 
certification as to the actual cost of the work performed in connection 
with the construction of the project on Form FmHA 1924-13 prior to 
final payment. The construction costs, as reported on Form FmHA 1924-
13, must be audited by a CPA, or LPA licensed on or before December 31, 
1970, in accordance with Government Auditing Standards, and certain 
agreed upon procedures (available in any FmHA office) performed in 
accordance with Attestation Standards. In some cases, FmHA will 
contract directly with a CPA or LPA for the cost certification. In that 
event, documentation necessary to have the costs of construction 
certified by an FmHA contractor that they were the actual costs of the 
work performed, as reported on Form FmHA 1924-13, will be provided. 
Funds which were included in the loan for cost certification and which 
are ultimately not needed because FmHA contracts for the cost 
certification will be returned on the loan.
    (A) The CPA or LPA's audit, performed in accordance with Government 
Auditing Standards, will include such tests of the accounting records 
and such other auditing procedures of the applicant/owner-builder (and 
any subcontractor, material supplier, or equipment lessor sharing an 
identity of interest) concerning the work performed, services rendered, 
and materials supplied in connection with the construction of the 
project he/she considers necessary to express an opinion on the 
construction costs as reported on Form FmHA 1924-13. Upon completion of 
construction and prior to final payment, the CPA or LPA will provide an 
opinion as to whether the construction costs as reported on Form FmHA 
1924-13 present fairly the costs of construction in conformity with 
eligible construction costs as prescribed in FmHA regulations. FmHA 
reserves the right to determine, upon receipt of the certified Form 
FmHA 1924-13 and the auditor's report, whether they are satisfactory to 
FmHA. At a minimum, the CPA or LPA shall also perform any additional 
agreed upon procedures (available in any FmHA office) specified by 
FmHA, performed in accordance with Attestation Standards, of the owner-
builder (and any subcontractor, material supplier, or equipment lessor 
sharing an identity of interest) concerning the work performed, 
services rendered, and materials supplied in connection with the 
construction. There will exist no business relationship between the CPA 
or LPA and the borrower except for the performance of the examination 
of the cost certification, accounting systems work, and tax 
preparation. Any CPA or LPA who acts as the borrower's accountant 
(performing manual or automated bookkeeping services or maintains the 
official accounting records) will not be the same CPA or LPA who cost 
certifies the project.
    (B) Prior to final payment to anyone required to cost certify, FmHA 
must be provided with a certification and a trade-item breakdown 
showing the actual cost compared to the estimated cost furnished in 
accordance with paragraph (e)(2)(i)(G) of this section. Form FmHA 1924-
13 is the form of comparative breakdown that must be used, and contains 
the certification required of the applicant/owner-builder prior to 
final payment. The amounts for builder's general overhead, general 
requirements, and builder's profit shall not exceed the amounts 
represented on the estimate of cost breakdown provided in accordance 
with paragraph (e)(2)(i)(G) of this section for the owner-builder or 
any subcontractor, material supplier, or equipment lessor having or 
sharing an identity of interest with the applicant/owner-builder. Final 
payment to the owner-builder will be adjusted, if necessary, to assure 
that the amounts shown on the certificate of actual cost do not exceed 
the amounts represented on the cost breakdown. Any funds remaining as a 
result of hard cost savings will be applied to the account as an extra 
payment or used for eligible loan purposes approved by FmHA as long as 
the improvements are genuinely needed and will enhance marketability of 
the project. All increases or decreases of 15 percent or more in line 
item costs will require documentation as to the reason for the 
increases or decreases. The State Director may require documentation 
for increases or decreases of less than 15 percent, if he/she 
determines it necessary. This information will be required with the 
cost certification.
    (C) Subcontracting development work.
    (1) Owner-builders will not be allowed to obtain a profit and 
overhead unless they are performing actual construction. ``Actual 
construction'' means ``work'' as defined in AIA documents: ``* * * 
labor, materials, equipment, and services provided by the contractor to 
fulfill the contractor's obligations.'' Under this definition, owner-
builders who choose to subcontract out construction of the project to 
another contractor will not obtain a builder's fee (general overhead 
and profit) when:
    (i) More than 50 percent of the total cost of the building 
construction is subcontracted to one subcontractor, material supplier, 
or equipment lessor, and/or
    (ii) Seventy-five percent or more with three or fewer 
subcontractors, material suppliers, and/or equipment lessors.
    (2) Note: If two or more subcontractors have common ownership, they 
are considered as one subcontractor.
    (3) How to apply rule:
    (i) The 50 percent rule will apply when division of the amount of 
the largest subcontract by the total amount of the building cost 
results in more than 50 percent.
    (ii) The 75 percent rule will apply when division of the sum of the 
amounts of the three largest subcontracts by the total building cost 
results in 75 percent or more.
    (D) Qualified contracting entities. Contractors, subcontractors, 
material suppliers, and any other individual or organization sharing an 
identity of interest and providing materials or services for the 
project must certify that it is a viable, ongoing trade or business 
qualified and properly licensed to undertake the work for which it 
intends to contract. Form FmHA 1944-31 will be prepared and executed by 
the contracting entities. The form provides notification to the 
entities of the penalty, under law, for erroneously certifying to the 
statements contained therein. Debarment actions will be instituted 
against entities who fail to disclose an identity of interest in 
accordance with the provisions of FmHA Instruction 1940-M (available in 
any FmHA office).
* * * * *
    4. Section 1924.50 is revised to read as follows:


Sec. 1924.50  OMB control number.

    The reporting and recordkeeping requirements contained in this 
regulation have been approved by the Office of Management and Budget 
(OMB) and have been assigned OMB control number 0575-0042. Public 
reporting burden for this collection of information is estimated to 
vary from 5 minutes to 4 hours per response, with an average of 37 
minutes per response, including time for reviewing instructions, 
searching existing data sources, gathering and maintaining the data 
needed, and completing and reviewing the collection of information. 
Send comments regarding this burden estimate or any other aspect of 
this collection of information, including suggestions for reducing this 
burden, to U.S. Department of Agriculture, Clearance Officer, OIRM, AG 
Box 7630, Washington, DC 20250; and to the Office of Management and 
Budget, Paperwork Reduction Project (OMB# 0575-0042), Washington, DC 
20503.

PART 1930--GENERAL

    5. The authority citation for part 1930 continues to read as 
follows:

    Authority: 42 U.S.C. 1480; 5 U.S.C. 301; 7 CFR 2.23 and 2.70.

Subpart C--Management and Supervision of Multiple Family Housing 
Borrowers and Grant Recipients


Sec. 1930.123  [Amended]

    6. Section 1930.123 is amended by revising in the first column of 
paragraph (i) the words ``Identity of Interest Disclosure Certification 
Memorandum'' to read ``Forms FmHA 1944-30, Identity of Interest (IOI) 
Disclosure Certificate, and FmHA 1944-31, Identity of Interest (IOI) 
Qualification Form.''
    7. Exhibit B of subpart C is amended by redesignating paragraphs V 
B 2 a and V B 2 b as paragraphs V B 2 b and V B 2 d, respectively, by 
revising newly redesignated paragraph V B 2 b, and by adding paragraphs 
V B 2 a and V B 2 c; by removing paragraph XIII B 2 a (1)(iii), by 
redesignating paragraph XIII B 2 a (1)(iv) as XIII B 2 a (1)(iii), and 
by revising paragraphs XIII B 2 a (1)(i), XIII B 2 a (1)(ii), and the 
introductory text of newly redesignated paragraph XIII B 2 a (1)(iii) 
to read as set forth below; and by revising in the first column of 
paragraph XIII C 2 f (3) the words ``Identity of Interest Disclosure 
Certification Memorandum'' to read ``Identity of Interest (IOI) 
Disclosure Certificate, Form FmHA 1944-30 and Identity of Interest 
(IOI) Qualification Form, Form FmHA 1944-31''.

Exhibit B of Subpart C--Multiple Housing Management Handbook

* * * * *
    V * * *
    B * * *
    2 * * *
    a  FmHA Forms 1944-30, ``Identity of Interest (IOI) Disclosure 
Certificate,'' and FmHA 1944-31, ``Identity of Interest (IOI) 
Qualification Form,'' (available in any FmHA Servicing office) will 
be completed and submitted as part of the management plan. 
Management agents will sign either form as ``applicant.''
    b  The initial disclosure shall be in effect for a period of 3 
years and renewed every 3 years thereafter, except if there are any 
changes in the business practices of the applicant/borrower and/or 
management entity during the interim years that include identity of 
interest concerns, the entity must file amended Forms FmHA 1944-30 
and FmHA 1944-31.
    c  The forms provide notification to the entities of the 
penalty, under law, for erroneously certifying to the statements 
contained therein.
* * * * *
    XIII * * *
    B * * *
    2 * * *
    a * * *
    (1) * * *
    (i) The initial operating capital must be in the form of cash as 
set forth in Sec. 1944.211 (a)(6) of subpart E of part 1944 of this 
chapter.
    (ii) The borrower will have deposited the required initial 
operating cash into the general operating account by the time of the 
FmHA loan closing or when interim financing funds are obtained, 
whichever occurs first. These funds will blend with other revenue 
that accrues to the account to cover budgeted expenditures including 
payment of return to owner.
    (iii) After 2, but before 5 full (12 month) borrower fiscal 
years of project operation, the borrower may request (in writing) 
the State Director's authorization to make a one-time withdrawal of 
the initial operating capital, or a part of it. The one-time 
withdrawal can never exceed the initial operating capital as 
described in the loan agreement or loan resolution. The withdrawal 
can be approved provided that:
* * * * *
    8. Exhibit B-3 of subpart C is amended by revising paragraph I D 
and the list of Attachments at the end of this exhibit to read as 
follows:

Exhibit B-3 of Subpart C--Sample Management Agreement for Farmers Home 
Administration (FmHA) Financed Multiple Family Housing (MFH) Projects

* * * * *
    I * * *
    D  Identity of interest. The Agent discloses to the Owner and 
FmHA any and all identities of interest that exist or will exist 
between the Agent and the Owner, suppliers of material and/or 
services, or vendors in any combination of relationship. Forms FmHA 
1944-30, ``Identity of Interest (IOI) Disclosure Certificate,'' and 
FmHA 1944-31, ``Identity of Interest (IOI) Qualification Form,'' 
completed by the Agent as ``applicant,'' are attached and made part 
of this agreement.
* * * * *
    Attachments: Management plan, Loan resolution or agreement, 
Identity of Interest Disclosure Certificate, Identity of Interest 
Qualification Form.


Exhibit B-8 of Subpart C  [Amended]

    9. Exhibit B-8 of subpart C is amended by revising in the first 
column the words ``Identity of Interest (IOI) Disclosure Certificate 
Memorandum'' to read ``Forms FmHA 1944-30, `Identity of Interest (IOI) 
Disclosure Certificate,' and FmHA 1944-31, `Identity of Interest (IOI) 
Qualification Form'.''

PART 1944--HOUSING

    10. The authority citation for part 1944 continues to read as 
follows:

    Authority: 7 U.S.C., 1989; 42 U.S.C. 1480; 5 U.S.C. 301; 7 CFR 
2.23; 7 CFR 2.70.

Subpart E--Rural Rental and Rural Cooperative Housing Loan 
Policies, Procedures, and Authorizations

    11. Section 1944.205 is amended by removing the definition for 
``Irrevocable letter of credit;'' by adding the definitions for 
``Servicing office'' and ``Servicing official;'' and by revising the 
definition for ``Initial operating capital'' to read as follows:


Sec. 1944.205  Definitions.

* * * * *
    Initial operating capital. Cash to pay for costs such as property 
and liability insurance premiums, fidelity coverage premiums if an 
organization, utility hookup deposits, maintenance equipment, movable 
furnishings and equipment, printing lease forms, and other initial 
operating expenses. The initial operating capital will be at least 2 
percent of the total development cost of the project.
* * * * *
    Servicing office. FmHA servicing office or other place designated 
by the FmHA State Director where loan requests are processed.
    Servicing official. FmHA servicing official or other FmHA staff 
member designated by the State Director to be responsible for 
processing loan requests.
* * * * *
    12. Section 1944.211 is amended by removing paragraph (a)(6)(iii); 
by redesignating paragraph (a)(6)(iv) as paragraph (a)(6)(iii); and by 
revising paragraphs (a)(4), (a)(6)(i) and (a)(6)(ii) to read as 
follows:


Sec. 1944.211  Eligibility requirements.

    (a) * * *
    (4) With the exception of a nonprofit organization, consumer 
cooperative or public body, provide from its own resources the borrower 
contribution required by Sec. 1944.213 (b) of this subpart. This 
contribution must be in the form of cash, land, or a combination 
thereof.
* * * * *
    (6) * * *
    (i) The applicant will provide a detailed list of all materials and 
equipment needed to be funded by the initial operating capital 
including, but not limited to, property and liability insurance 
premiums, fidelity bond premiums when the applicant is an organization, 
utility hook-up charges and deposits, maintenance and other equipment, 
lease forms, furnishings, loan payments that may become due during 
construction, purchase of office equipment and furniture, community 
room furnishings, other movable equipment and furnishings, congregate 
items referenced in Sec. 1944.224 of this subpart, advertising 
expenses, management fees, etc. The list will be approved by the 
servicing office based upon similar projects in the State. The initial 
2 percent operating and maintenance (O&M) expenses, plus any amounts 
needed for these items above the 2 percent, must be provided in cash.
    (ii) The O&M cash will be deposited into the general operating 
account in accordance with the provisions of the loan agreement or loan 
resolution. FmHA will be provided with documentation of the deposit 
prior to the start of construction or loan closing (whichever is first) 
and such funds will be used for authorized purposes only.
* * * * *
    13. Section 1944.212 is amended by adding paragraph (c)(3)(iii) and 
by revising the introductory text of paragraph (b), paragraphs (c)(1), 
(c)(2), (c)(3)(ii), (g), (i), and the introductory text of paragraph 
(j) to read as follows:


Sec. 1944.212  Loan and grant purposes.

* * * * *
    (b) Purchase and rehabilitate existing buildings only when the loan 
for such rehabilitation does not exceed by 5 percent the loan for new 
construction in the same area and when moderate or substantial 
modifications, repairs or improvements to the structures are necessary 
to meet the requirements of decent, safe, and sanitary living units.
* * * * *
    (c) * * *
    (1) Loan funds used to purchase land may not exceed the estimated 
market value of the site in its present condition as shown by a current 
appraisal in accordance with FmHA Instruction 1922-B (available in any 
FmHA office).
    (2) With prior written approval of the State Director, loan funds 
may be used to buy land from a member of a broadly-based nonprofit 
applicant/organization.
    (3) * * *
    (ii) The cost of the excess land is a reasonable portion of the 
loan; and
    (iii) The site density requirements of Sec. 1944.215(a)(6) of this 
subpart are met.
* * * * *
    (g) Purchase and install ranges, refrigerators, drapes, blinds/
shades, drapery rods, and clothes washers and dryers. Laundry 
facilities are required in all projects and clothes washers and dryers 
should be provided in a central laundry room. Normally, a minimum of 
one washer and dryer should be provided for every 8 to 12 units in a 
project. Clothes washers and dryers may not be installed in individual 
units if the installation is not customary in the area for the size of 
project and type of housing involved. In any case, both central and 
individual laundry facilities will not be provided in a single project.
* * * * *
    (i) Pay related costs such as fees and charges for market studies, 
tax credit application, legal (costs pertaining to the closing of the 
FmHA loan only), archeological, architectural, engineering, 
environmental, and other appropriate technical and professional 
services. The fees and charges may be paid to an applicant or officer, 
director, trustee, stockholder, member, or agent of the applicant 
provided those fees and charges are reasonable and typical for the area 
and are earned and the identity of interest is disclosed. Legal, 
technical, and professional fees do not include the costs incurred in 
the formation or incorporation of the limited profit applicant, costs 
of syndication, or the payment of a loan packaging or development fee.
    (j) Provide loan funds to enable a nonprofit group or public body 
to pay fees for technical assistance received from a nonprofit 
organization, with housing and/or community development experience, to 
assist it in the formation or incorporation and development and 
packaging of its loan docket and project, as well as legal, technical 
and professional fees incurred in the formation or incorporation of the 
applicant entity.
* * * * *
    14. Section 1944.213 is amended by removing paragraph (c)(12); by 
redesignating paragraphs (b)(4), (b)(5), and (b)(6) as paragraphs 
(b)(5), (b)(6), and (b)(7), respectively; by adding paragraph (b)(4); 
and by revising paragraphs (c)(6), (c)(10), the introductory text of 
paragraph (d), paragraph (d)(1)(ii), and the introductory text of 
paragraph (e)(1) to read as follows:


Sec. 1944.213  Limitations.

* * * * *
    (b) * * *
    (4) The examples set forth in Exhibit A-13 of this subpart 
(available in any FmHA office) provide clarity in determining the 
proper loan amount for various types of loans.
* * * * *
    (c) * * *
    (6) Facilities contrary to cost containment measures defined in 
Sec. 1944.215 (a) of this subpart.
* * * * *
    (10) Land which the applicant or a member of an applicant/
organization owns or land which is owned by any other organization in 
which any member of the applicant/organization has an interest, or has 
had an interest within the last 3 years, including any commission due 
on the sale thereof, except as authorized in Sec. 1944.212(c)(2) of 
this subpart.
* * * * *
    (d) Obligations incurred before loan closing. When an applicant 
files a preapplication for a loan, the servicing official will advise 
the applicant not to start construction or incur any indebtedness until 
the loan is closed, except for those cases involving interim financing; 
the guidelines outlined in Sec. 1944.235(c)(1) of this subpart will 
then apply. During the period of preapplication review and processing, 
applicants will not take any actions with respect to their applications 
which would have an adverse impact on the environment or limit the 
choice of reasonable alternatives. This requirement does not preclude 
the applicant from developing preliminary plans or designs or 
performing other work necessary to support an application for Federal, 
State, or local permits or assistance. If the applicant incurs debts 
for work, materials, land purchase, or other authorized fees and 
charges before the loan is closed, the State Director may authorize the 
use of loan funds to pay the debts when all of the following conditions 
exist and debts were authorized in writing by FmHA prior to their being 
incurred (market studies will be exempt from this requirement):
    (1) * * *
    (ii) Prior to the date of preapplication as part of a 
predevelopment loan specifically intended as temporary financing from a 
public agency or nonprofit organization and the State Director secures 
prior concurrence from the National Office; or
* * * * *
    (e) * * *
    (1) No increase in per unit development cost will be approved, 
whether the circumstance causing the cost increase occurs before, 
during, or after the construction period, unless these conditions were 
unforeseen factors beyond the owner's control and the increase in cost 
was approved by FmHA in writing before the expense was incurred. (In 
case of an emergency, the requirement that the cost be approved by FmHA 
in writing before the expense is incurred is waived as long as the 
servicing official is notified by the next working day.) Such costs 
are:
* * * * *
    15. Section 1944.215 is amended in paragraph (b)(1)(iii) by adding 
the words ``(available in any FmHA office)'' at the end of the 
paragraph; by revising in paragraph (h)(1) the words ``What is 
Cooperative Housing?'' to read ``A Guide to Cooperative Housing''; and 
by revising paragraph (a), the introductory text of paragraphs (b) and 
(b)(1), paragraph (b)(1)(i), and the introductory text of paragraph (e) 
and by adding paragraph (w)(3) to read as follows:


Sec. 1944.215  Special conditions.

    (a) Cost containment. To achieve affordable rents and occupancy 
rates (not considering rental assistance or similar subsidies), all 
development costs will be economical in nature and not include costs 
for unnecessary or elaborate design features. Cost containment is not 
to be interpreted as accepting poor design or cheap construction. 
Projects must provide the features and amenities necessary for the 
lifestyles of the tenants and members. Consideration must be given to 
the cost/benefit ratio when evaluating, recommending, or requiring 
specific design features or construction techniques. Life cycle cost 
analysis will be employed to determine the types of materials which 
will reduce operation/maintenance costs even though their initial costs 
are higher. Operation and maintenance costs factored into proposed 
operating budgets will be adjusted accordingly. The following 
guidelines are to be followed when developing projects:
    (1) Each State architect/engineer (A/E) will compile and maintain 
data on costs of all projects. Total project estimates will be compared 
with estimates available through the Marshall & Swift computer program. 
These estimates, along with the line item costs recorded in FmHA's 
Automated Multi-Housing Accounting System (AMAS) cost tracking system, 
will be used to establish a benchmark for future project costs. Any 
proposal that exceeds these costs must be carefully evaluated for 
possible cost reductions. The borrower will be responsible for 
resolving the differences in cost to bring the project into line with 
the lesser of the cost tracking system or Marshall & Swift estimates. 
Final determinations must be realistic, interrelated to maintenance and 
operation costs, and based upon local conditions and common sense. The 
State will consider circumstances such as high land costs, remote rural 
areas, etc., which could present a problem in achieving such an 
alignment of costs. The AMAS cost tracking system will be used to 
record both estimates and actual line item costs. At the time the 
preapplication estimates are being examined by FmHA, the percentages 
for builder's profit, general overhead, and general requirements will 
be calculated to determine if they are within the allowable percentages 
established in this paragraph. They will again be calculated at the 
time the final estimates are submitted to FmHA. Estimated amounts in 
excess of the allowable percentages will be reduced to the appropriate 
percentage. Once the final estimates are approved by FmHA, payment of 
builder's profit, general overhead, and general requirements will not 
exceed the estimated amounts. Allowable percentages for builder's 
profit, general overhead, and general requirements will not exceed 10 
percent, 4 percent, and 7 percent, respectively. This will not be 
interpreted to mean that, if historical percentages for these costs 
were below 10, 4, and 7, respectively, FmHA will allow the costs to be 
increased automatically. Adequate justification and documentation will 
be required to approve an increase to 10, 4, or 7 percent for cases 
where any of the costs were previously below those levels.
    (2) The elimination or reduction of unnecessary delays in 
application processing can contribute to cost containment through lower 
interest and other business expenses on land, inventory, tests, design 
studies, etc. When reasonable processing timeframes are established, 
known and followed, appropriate time can be planned for preparing 
quality application and construction documents. This can result in 
better instructions to the builder, fewer errors and lower construction 
costs.
    (3) Most materials and systems are available in a range of 
qualities and prices. The construction documents will be carefully 
reviewed for specifications that require qualities or grades higher 
than necessary. These specifications will be accepted only if fully 
justified and no reasonable alternatives are available.
    (4) Designs which employ standard building material dimensions and 
reduce waste will be used.
    (5) Sites will require a minimum amount of site development work. 
The State Director may authorize a site requiring higher than normal 
site development costs only if:
    (i) The proposed site and site development costs are less than the 
cost of the normal site and site development costs; or
    (ii) There are no other sites available in the market area with a 
lower combined cost.
    (6) All project site densities (units per acre) will be within the 
following ranges, regardless of site conditions unless local zoning 
requirements dictate otherwise:

------------------------------------------------------------------------
                                                        Minimum  Maximum
                                                                        
------------------------------------------------------------------------
One-story buildings...................................       10       14
Two-story buildings...................................       14       18
Three or more story buildings.........................       18      22 
------------------------------------------------------------------------

    (i) For example: A 24-unit project composed of two-story buildings 
must have a site of at least 1.3 acres. FmHA will finance the purchase 
and development of larger sites, but not more than 1.7 acres. Ranges 
for projects with a mixture of building heights can be interpolated.
    (ii) An exception may be made to this provision only if the site in 
question is the only site available in the market area and its size, 
shape, or condition makes a portion of the site unsuitable for 
building. An exception to this requirement must be granted by the State 
Director or a designee. The applicant must provide written 
documentation that no other sites are available.
    (7) Sound judgment and common sense must also be used in 
construction inspections and final acceptance of projects. Field staff 
involved in these activities must be careful not to impose additional 
or unreasonable requirements on the builder that will increase 
construction costs. States should consider hiring enough construction 
inspectors to provide more than the required inspections and to allow 
multiple unscheduled and unannounced visits. The State Office may also, 
with National Office authorization, contract for inspection services to 
deter deviations from the FmHA-accepted construction documents. 
Prefinal and final inspections must be conducted by qualified FmHA 
personnel.
    (8) Buildings will not include numerous wall and roof breaks, 
unusual designs requiring excessive corners and foundation off-sets, or 
that require more exterior entrances than absolutely necessary. Designs 
will not be considered acceptable that place dining facilities in 
structures attached to the main building when these amenities can be 
less expensively included within the main structure.
    (9) Buildings will not include roof slopes less than 3/12 nor 
greater than 6/12 unless otherwise required by local authorities or in 
order to accommodate severe weather conditions.
    (10) The use of repeat designs will be required from applicants 
whose architects have designed projects previously approved by FmHA. 
This does not mean ``cloned'' projects are required throughout the 
State and/or region. When a repeat design is being used in the same 
community, the exterior facade (such as color, siding material, etc.) 
must be noticeably changed except in the case of subsequent phases. The 
State Office architect will ensure that sufficient differences are 
included in the proposed plans which will preclude the appearance of 
``cloned'' designs. ``Predesigned'' buildings must fit the basic 
existing contours of the proposed site.
    (11) The following facilities are considered nonessential and will 
not be included in the loan unless required by local codes or 
ordinances:
    (i) Garages/covered parking;
    (ii) Bay/box/picture or similar type windows;
    (iii) Fireplaces;
    (iv) Community room furniture;
    (v) Sliding glass/atrium or similar type doors;
    (vi) Materials atypical for the area;
    (vii) Atriums/solariums;
    (viii) Saunas;
    (ix) Whirlpools;
    (x) Gyms (facilities to accommodate physical exercises may be 
included in elderly projects without regard to this restriction); and
    (xi) Swimming pools.
    (12) Other design features which will only be accepted if 
determined customary for the area are:
    (i) Patios/balconies (minimum size which will accommodate 
handicapped accessibility);
    (ii) Washer and dryer hookups in individual units; and
    (iii) Washers and dryers in individual units.
    (13) The following is a list of allowable amenities according to 
the type of units: 

----------------------------------------------------------------------------------------------------------------
                                                      Family         Elderly        Congregate      Group home  
----------------------------------------------------------------------------------------------------------------
Active outdoor recreation.......................  Yes...........  No............  No............  Yes.          
Carpet..........................................  Yes...........  Yes...........  Yes...........  Yes.          
Central laundry facilities......................  Yes...........  Yes...........  Yes...........  Yes.          
Community rooms.................................  No............  Yes...........  Yes...........  Yes.          
Dishwashers.....................................  No............  Yes...........  Yes\1\........  \1\Yes.       
Drapes/blinds/shades............................  Yes...........  Yes...........  Yes...........  Yes.          
Elevators for 2-story elderly...................  No............  Yes...........  Yes...........  No.           
Garbage disposals...............................  No............  No............  Yes\1\........  \1\Yes.       
Lawn sprinklers--financing will depend on geographic area. .....................................................
----------------------------------------------------------------------------------------------------------------
\1\In central kitchens only.                                                                                    

    (14) Total on-site parking spaces per living unit will be within 
the following ranges unless otherwise required by local authorities:


    Note: Additional spaces for visitors, staff, or health care 
workers may be provided.

------------------------------------------------------------------------
     Family            Elderly          Congregate            Group     
------------------------------------------------------------------------
  Min      Max      Min      Max       Min       Max      Min      Max  
------------------------------------------------------------------------
1.0....    1.5      0.5      1.0      0.25       1.0     0.25     0.5   
------------------------------------------------------------------------

    (15) Management, maintenance, and community rooms should be in 
accordance with Guide 2 of subpart A of part 1924 of this chapter 
(available in any FmHA office). Laundry rooms should be no larger than 
necessary to accommodate equipment, circulation (including handicapped 
accessibility) and areas for sorting and folding clothes.
    (b) Type of housing. All housing will be designed to:
    (1) Be economically constructed and not of elaborate design or 
materials. All new construction will conform with the applicable 
development standards of Sec. 1924.5(d)(1) of subpart A of part 1924 of 
this chapter. The gross square foot living area of new units will be 
within the ranges listed below. Living area is defined as: All enclosed 
space for the unit (except unfinished storage space for outdoor items 
and space needed for heating and/or cooling equipment) and measured 
from the exterior surface of the framing of exterior walls and the 
center line of interior party or corridor walls. States should 
establish ranges within these dimensions to be commensurate with unit 
sizes in the local market. For example, when conventional units in the 
market are at the low end of FmHA's range scale, FmHA will also build a 
comparably smaller unit. 

------------------------------------------------------------------------
                                                               Minimum/ 
                                                                maximum 
                        Type of unit                            living  
                                                               area (sq.
                                                                 ft.)   
------------------------------------------------------------------------
0-Bedroom Unit..............................................  350-500   
1-Bedroom Unit..............................................  500-650   
2-Bedroom Unit..............................................  650-800   
3-Bedroom Unit..............................................  800-950   
4-Bedroom Unit..............................................  950-1100  
------------------------------------------------------------------------

    (i) An additional 100 to 120 square feet of living area may be 
added to the 4-bedroom unit guideline for each bedroom in excess of 
four. Floor areas for living and dining rooms should comply with Guide 
2 of subpart A of part 1924 of this chapter (available in any FmHA 
office). The maximum square footage in congregate housing units will 
not exceed 110 percent of the minimum square footages listed above.
* * * * *
    (e) Loan resolution or loan agreement. The loan resolution or loan 
agreement contains provisions of policy and procedure which should be 
carefully read, fully understood by the applicant, and executed by the 
applicant prior to loan approval. If any provisions are not appropriate 
to a particular case, proposed substitute language must be approved by 
FmHA and OGC. Subpart C of part 1930 of this chapter provides for the 
maintenance of certain accounts and the pledge of housing income as 
security. It contains regulatory provisions governing and giving FmHA 
power to impose requirements regarding the housing and related 
operations of the applicant. All sections and requirements determined 
applicable by OGC will form part of any other loan resolution or 
agreement that may be submitted by the applicant. These are:
* * * * *
    (w) * * *
    (3) Feasibility for projects receiving tax credits will require a 
more extensive examination since tax credits are predicated on renting 
to very-low income persons. Applicants choosing to apply for tax 
credits will be responsible for identifying the amount of tax credits 
it anticipates requesting from the State, as well as the income 
percentage on which the credits will be based, and the percentage of 
units targeted for tax credit eligible persons. The market study must 
substantiate the presence of persons whose incomes would qualify for 
tax credits who cannot afford the basic rent and those persons whose 
incomes are tax credit eligible but who are still able to afford the 
basic rent.
* * * * *


Sec. 1944.222  [Amended]

    16. Section 1944.222 is amended in paragraph (g) by adding the 
words ``from the current owner of public record'' at the end of the 
first sentence.


Sec. 1944.224  [Amended]

    17. Section 1944.224 is amended in paragraph (a)(3)(i) by revising 
the reference to ``Sec. 1944.211 (a)(6)(ii)'' to read ``Sec. 1944.211 
(a)(6)(i).''
    18. Section 1944.231 is amended by removing the definitions for 
``District Director'' and ``District Office'' in paragraph (a), by 
redesignating paragraphs (e)(2) through (e)(4) as paragraphs (e)(3) 
through (e)(5), respectively, by adding a paragraph (e)(2), and by 
revising the introductory text of paragraph (e) to read as follows:


Sec. 1944.231  Processing preapplications.

* * * * *
    (e) Determining eligibility and feasibility. After rating the 
preapplication, if the priority processing point score is sufficient to 
potentially authorize issuance of an AD-622 inviting a formal 
application within the next 24 months (except for RCH preapplications), 
the servicing official will review the proposal to determine 
eligibility, feasibility, and compliance with loan purposes, policies, 
and regulations. Eligibility/feasibility reviews will be completed in 
priority point score order. Where a tie in priority point score exists, 
the order of review will be determined in accordance with paragraph 
(c)(5) of this section. In cases where the market study is incomplete 
or not in accordance with Exhibit A-8 of this subpart, applicants will 
be required to have the study supplemented to agree with FmHA 
requirements. The time involved in supplementing the market study will 
cause the preapplication to be delayed in determining feasibility.
* * * * *
    (2) In those cases where the need for new rental units is 
questioned by the servicing official, another market study may be 
obtained by the servicing office at its discretion through contract 
with a market analyst. The same market analyst who provided an 
assessment for the applicant will not be used. Issuance of all AD-622s 
in that market area will be delayed until the FmHA market study has 
been completed and its contents reviewed by FmHA.
* * * * *
    19. Section 1944.235 is amended by removing paragraph (a)(1); by 
redesignating paragraphs (a)(2) through (a)(5) as paragraphs (a)(1) 
through (a)(4), respectively; by revising newly redesignated paragraph 
(a)(2) and the introductory text of paragraph (c)(1); and by adding 
paragraphs (b)(3) and (c)(1)(viii) to read as follows:


Sec. 1944.235  Actions subsequent to loan approval.

    (a) * * *
    (2) Ensure that the servicing office has on file evidence that a 
deposit has been made to the general operating account of an amount of 
initial operating capital sufficient to cover the expected start-up 
costs.
* * * * *
    (b) * * *
    (3) Monetary default by original applicant/entity. An obligation 
may be transferred to any person or applicant eligible to receive an 
RRH loan when the original applicant/entity is in monetary default 
which has or may result in foreclosure by the interim lender, and:
    (i) The applicant/entity assuming the obligation, or the interim 
lender, removes any liens filed against the property;
    (ii) There have been no deviations from the FmHA approved plans and 
specifications;
    (iii) The transferee will not be composed of any principals of the 
transferor;
    (iv) The transfer will be in the best interest of the FmHA and 
prospective tenants;
    (v) The applicant/entity and all members thereof whose obligations 
are transferred will not be considered eligible for further 
participation in the RRH program for at least 5 years from the date of 
the transfer of the FmHA loan obligation; and
    (vi) Prior approval is obtained from the National Office.
    (c) * * *
    (1) Interim financing. When the amount of the loan exceeds $50,000, 
the applicant may obtain interim financing from commercial or public 
sources for the construction period if it can be obtained at reasonable 
interest rates, fees, and terms, and in the best financial interests of 
the Government. Interim financing will be obtained to preclude the 
necessity for multiple advances of FmHA funds. The interim lender must 
be authorized to operate in the State in which the project will be 
located and must have an established record of providing financing to 
entities other than FmHA-financed projects. Since the interim lender is 
responsible for inspecting construction along with FmHA, the borrowing 
entity (including any of its identity of interest entities) cannot 
provide interim financing to its own project. Interim financing will be 
used subject to the following:
* * * * *
    (viii) Because interest rates can fluctuate between the time 
construction estimates are finalized and completion of construction, 
any excess funds remaining from interim financing will be returned on 
the FmHA loan. Also, interim funds remaining because of early 
completion of construction will be returned. The leftover interest may 
be used for certain other eligible loan purposes critical to the 
completion of the project which were unknown to the applicant and 
contractor at the time the loan was approved, provided prior National 
Office concurrence is obtained.
* * * * *


Sec. 1944.236  [Amended]

    20. Section 1944.236 is amended in paragraph (c)(3) by revising the 
reference ``Sec. 1944.215 (d)'' to read ``Sec. 1944.215 (c).''
    21. Section 1944.237 is amended by revising paragraphs (a) and 
(c)(2) to read as follows:


Sec. 1944.237  Subsequent loans.

    (a) A subsequent loan is made to an applicant/borrower to complete, 
improve, repair, and/or make modifications to the project initially 
financed by FmHA, or for equity and/or other purposes when authorized 
by the provisions of subpart E of part 1965 of this chapter to avert 
prepayment. A subsequent loan to develop additional units must be rated 
and ranked in accordance with the priority point system contained in 
Sec. 1944.231 of this subpart. Other subsequent loan requests do not 
have to compete for funding under the priority point system.
* * * * *
    (c) * * *
    (2) If the initial investment and 2 percent O and M amounts are 
sufficient to cover only the initial FmHA loan, the applicant/borrower 
must provide the additional respective amounts to cover the subsequent 
loan. The 2 percent O and M amounts must be in the form of cash as 
described in Sec. 1944.211 (a)(6) of this subpart. The required amount 
of the initial investment is described in Sec. 1944.213 (b) of this 
subpart.
* * * * *
    22. Exhibit A of subpart E is amended by revising paragraph VIII to 
read as follows:

Exhibit A of Subpart E--How To Bring Rental and Cooperative Housing to 
Your Town

* * * * *

VIII  Exhibits

    The following exhibits may be used when applicable and, if 
necessary, adapted to meet the specific needs of applicants.

Exhibit
    A-1  Legal Services Agreement
    A-2  Survey of Existing Rental Housing
    A-3  Rental Housing Survey
    A-4  Cooperative Housing Survey
    A-5  Housing Survey Summary
    A-6  Housing Allowances for Utilities and Other Public Services
    A-7  Information to be Submitted with Preapplication for a Rural 
Rental Housing (RRH) or a Rural Cooperative Housing (RCH) Loan
    A-8  Outline of Professional Market Study
    A-9  Information to be Submitted with Application for Rural 
Rental Housing (RRH) and Rural Cooperative Housing (RCH) Loans
    A-10  Administrative Process for Combining Farmers Home 
Administration (FmHA) Assistance with Low-Income Housing Tax Credits
    A-11  Processing Guidelines for Loans for Equity to Avert 
Prepayment
    A-12  Market Study Checklist (available in any FmHA office)
    A-13  Work Sheet for Loan Calculation (available in any FmHA 
office)
    A-14  Information to be Submitted for Subsequent Loans 
(available in any FmHA office)

    23. Exhibit A-7 of subpart E is amended by adding the words 
``subpart V,'' after the words ``part 3015,'' in paragraph VII; by 
adding paragraph II.J; and by revising the introductory text of 
paragraph I.A., and paragraphs I.A.(3), I.A.(6), the introductory text 
of paragraph I.A.(7), I.H., II.A., the introductory text of paragraph 
II.B., paragraphs II.C., II.F., the last sentence of paragraph II.G, 
III.C., and IV.F to read as follows:

Exhibit A-7 of Subpart E--Information to be Submitted With 
Preapplication for a Rural Rental Housing (RRH) or a Rural Cooperative 
Housing (RCH) Loan

* * * * *

I. * * *

    A. Financial Statements for Rental Projects--Each applicant must 
submit a current, signed, and dated financial statement. The 
financial statement must reflect sufficient financial capacity to 
meet the applicant's equity capital and initial operating capital 
requirements. Applicants may contribute cash, free and clear title 
to the building site, or a combination of both as an equity 
contribution. The initial operating capital must be furnished in 
cash.
* * * * *
    (3) A financial statement will be required for limited partners 
in a limited partnership who will have 10 percent or more ownership.
* * * * *
    (6) When the applicant and/or general partner(s) have multiple 
applications pending and/or when the State Director is uncertain of 
the applicant's ability to provide the necessary borrower 
contribution required by Sec. 1944.213 (b) of this subpart, 2 
percent initial capital contribution and/or other assets needed for 
a sound loan, the State Director may request the applicant to submit 
additional financial information relative to its financial position. 
This information may be obtained from 6- to 12-month projected pro 
forma statements with supporting schedules.
    (7) All financial statements submitted must contain the 
following statement immediately preceding the signature line:
* * * * *
    H. Farmers Home Administration (FmHA) requires that applicants 
disclose identities of interest that will exist in the development 
of the proposed housing. Forms FmHA 1944-30, ``Identity of Interest 
(IOI) Disclosure Certificate,'' and 1944-31, ``Identity of Interest 
(IOI) Qualification Form,'' (available in any FmHA office) will be 
completed and submitted as part of the preapplication package.
* * * * *

II. * * *

    A. Economic justification and project size should be based on 
the housing need and demand from eligible prospective tenants or 
members who are permanent residents of the community and its 
surrounding trade area. Since the intent of the program is to 
provide adequate housing for the eligible permanent residents of the 
community, temporary residents of a community (such as college 
students in a college town, military personnel stationed at a 
military installation within the trade area, or others not claiming 
their current residence as their legal domicile) should be 
discounted in determining need and project size. The market study 
will reflect the types and sizes of units which are needed in the 
market area. For example, if the full market analysis shows a need 
for one-bedroom, two-bedroom, three-bedroom, and four-bedroom units, 
the preapplication must contain a percentage of three- and four-
bedroom units to correspond to the need expressed by the market 
study in order to accommodate the larger families. The need will not 
be based on persons who own their own homes but will be derived 
from:
    (1) Persons migrating into the area;
    (2) Persons dwelling in family units who desire to move into 
their own units (elderly persons living with family members will 
only be considered if evidence of their interest in moving into the 
project is furnished with the market study);
    (3) Conservative estimate (not to exceed 20 percent) of 
households living in substandard rental housing (lacking complete 
plumbing facilities or 1.01 or more persons per room). (A higher 
percentage will be allowed only if it can be clearly documented by 
signed survey sheets, developed expressly for this purpose, that 
occupants of more than 20 percent of the occupied substandard rental 
units are willing and able to move into the proposed project.);
    (4) Demolition of rental stock;
    (5) Allowance for a 5 percent vacancy rate in the growth of 
households since the last census; and
    (6) Conservative estimate (not to exceed 20 percent) of 
households experiencing rent overburden provided the analyst has 
made a determination there are sufficient households in the market 
area to occupy any rental units vacated by those lower income 
persons who choose to move into the proposed project from the 
existing units.
    B. A detailed study based upon data obtained from census 
reports, State or county data centers, individual employers, 
industrial directories, or chambers of commerce is required. FmHA 
personnel will utilize the market study checklist found at Exhibit 
A-12 of this subpart (available in any FmHA office) as a means for 
measuring market study credibility. The study will include:
* * * * *
    C. Exhibit A-8 of this subpart outlines the information which 
professional rental market studies will be required to follow. The 
qualifications of the person preparing the market study should 
include some housing or demographic experience. The market study 
will be used by FmHA in evaluating market feasibility but will not 
be the sole factor in such a determination. The data and information 
provided in the market study will be used to supplement FmHA's 
knowledge of the market area and to facilitate rational judgment 
concerning the need for new rental units. Other considerations will 
be FmHA's experience with the housing market in the State and local 
area and U. S. Department of Housing and Urban Development's (HUD's) 
analysis of market feasibility for the proposed units.
* * * * *
    F. The analyst must affirm that he/she actually made an on-site 
visit to the market area and that failure to do so may result in 
denial of further participation in the section 515 program by the 
analyst.
    G. * * * The Cooperative Housing Survey form located at Exhibit 
A-4 of this subpart and in ``A Guide to Cooperative Housing'' may be 
used for this purpose.
* * * * *
    J. Identification of the amount of tax credit units anticipated 
to be requested from the State Agency, the income percentage on 
which the credits will be based, and the percentage of project units 
targeted for tax credit eligible persons. This information is needed 
to determine the levels of incomes in the market area which will 
support the basic rents while also qualifying the borrower for tax 
credits.

III. * * *

    C. The applicant will provide evidence of having control of the 
proposed site either by ownership or by executing an option to buy 
with the current owner of public record.

IV. * * *

    F. A detailed cost breakdown of the project on Form FmHA 1924-
13, ``Estimate and Certificate of Actual Cost,'' will be prepared 
and submitted by all applicants. In addition to completing the 
individual line items, the cost of items such as rights-of-way, 
equipment, and utility connections must be included and identified 
with the Form FmHA 1924-13. Off-site improvements and the method of 
prorating the cost between eligible and noneligible loan items must 
be provided with the Form FmHA 1924-13. The cost breakdown must also 
separately show items not included in the loan, such as furnishings, 
equipment, and the noneligible off-site improvements. The trade item 
cost breakdowns must be updated just prior to loan approval.
* * * * *
    24. Exhibit A-8 of subpart E is revised to read as follows:

Exhibit A-8 of Subpart E--Outline of Professional Market Study

    Market studies which do not address all segments of this outline 
will not be considered acceptable and may adversely affect the 
processing of preapplications. Preapplications with unacceptable 
market studies may be returned, deferred, or rejected, as determined 
appropriate by the servicing office.
    The following information is to be used by analysts in the 
preparation of market studies for the Section 515 housing program. 
It generally contains the type and depth of information which 
Farmers Home Administration (FmHA) requires for evaluating the 
feasibility of prospective housing developments. The analyst will be 
expected to provide sufficient quantitative data (such as census 
tables), primary data (such as survey of existing comparables), and 
qualitative data (such as local contacts in the community) to 
support the conclusions reached. The analyst may present any other 
discussions and/or data which will help support the complete 
analysis of the market.
    The outline provides for the demonstration of historical trends 
and allows the analyst to project into the 2 years beyond the last 
actual year of record. Additional guidance is offered in individual 
segments of the outline. You will need to provide a statement of 
your experience and why you think you are qualified to prepare such 
a study.
    Determination of need and demand will be derived for prospective 
rental tenants only from: (1) Persons migrating into the area, (2) 
persons dwelling in family units who desire to move into their own 
units (elderly living with family members will only be considered if 
evidence of their interest in moving into the project is furnished 
with the market study), (3) conservative estimate (not to exceed 20 
percent) of households living in substandard rental housing, (4) 
demolition of rental stock, (5) allowance for a 5 percent vacancy 
rate, and (6) conservative estimate (not to exceed 20 percent) of 
households experiencing rent overburden provided the analyst has 
made a determination there are sufficient households in the market 
area to occupy any rental units vacated by those lower income 
persons who choose to move into the proposed project from the 
existing units. Substandard is defined as (1) Units lacking complete 
plumbing and (2) overcrowded (1.01 or more persons per room).
    For proposed congregate projects, the analyst will be 
responsible for researching the current need for, and usage of, 
services in the market area. The types of services being used, the 
provider of the services, and their location will be included.
    Homeowners will not be included in the determination of need and 
demand for rental units. The analyst will discuss the current market 
for single family houses and how sales, or the lack of, will affect 
the demand for elderly rental units. If the economic conditions 
reflect a trend toward normal selling times for houses in the market 
area, then the discussion should point to how elderly homeowners may 
reinforce the need, but only as a secondary market and not as the 
primary market.
    A statement, with signature, certifying that the analyst 
(including an individual under contract to the analyst's company) 
actually traveled to and physically surveyed the community where the 
proposed project will be located is also required.

I. Market Area--General

    The market area will be the community where the project will be 
located and only those outlying rural areas which will be impacted 
by the project (excluding all other established communities). Except 
in specific cases of congregate housing projects where an expanded 
market may be justified, the market area will not include the entire 
county (or parish, township, or other subdivision). Any deviation 
from this definition must be coordinated with the servicing office. 
The market area must be realistic. The criteria for selection should 
be described by the analyst. A map showing the market area will be 
required. The following is an example of a market area description:
    A. Based on an analysis of population and housing development 
patterns, major employers and commuting patterns, the effective 
market area for the subject proposal is defined to include all of 
(Name), 35 percent of (Name) and 25 percent of (Name) census 
divisions. This area is shown on Map 2 following Table 4 (page 11) 
in Section II of this report. In 1980, this geographic market area 
contained an estimated 6,350 persons (6.1 percent of the county 
total of 103,829 persons). During the 1970's decade, the overall 
market area experienced growth of 1,253 persons (representing 13.5 
percent of total gains in the county). In 1990, the (Name) market 
area population of 7,603 represented 6.7 percent of the county 
population of 113,086. (See Table 4 and Map 2 in Section II for 
details.)
    B. The effective market area for the subject proposal includes 
the town of (Name) and a portion of the unincorporated areas to the 
east and south. The (Name) River forms a natural barrier restricting 
development to the west. Housing development and population growth 
have occurred along major transportation corridors, particularly 
Interstate 81 and U.S. 11 between (Name) and (Name). Secondary 
growth has occurred along State Roads 63 and 68 to the northwest and 
southeast of (Name). The Interstate Industrial Park, with 16 
employers providing 999 jobs, is centrally located within the market 
area.

II. Site

    This section will contain a full description of the site, its 
position in the community and location with respect to residential 
support services.
    A. The proposed site is located in the eastern section of (Town) 
on (Major Thoroughfare). The area surrounding the site is 
predominantly comprised of modest single family dwellings. The 
terrain is gently sloped, with grass, oak trees, and some shrubs.
    B. The site is currently zoned for commercial business and is 
currently owned by a local car dealer.
    C. The site is approximately .3 mile east of the heart of town 
which contains a grocery store, drugstore, restaurants, banking 
facilities, the post office, and town hall. Other shopping is 
available .2 mile south at (Town) Plaza.
    D. The medical clinic, which provides services of an osteopath, 
X-ray technician, a physician's assistant, and a nurse, is 
approximately .8 mile north of this site. This clinic is open daily 
and also provides 24-hour emergency service. The nearest hospitals 
are (Large Town) and (Town).
    E. All public services are available at the site.
    F. Photographs of the site are required.
    G. Communities suitable for multi-family projects may have 
certain smaller businesses necessary for the day-to-day living 
convenience of the tenants and to supplement the employment base. 
For example, these may include, but not be limited to, pharmacy, 
restaurants and fast food establishments, grocery and department 
stores, hardware and sundries, etc. A representative number of these 
businesses are to be listed (by name) and location with respect to 
the proposed site.

Name of business and street address

----------------------------------------------------------------------

----------------------------------------------------------------------

----------------------------------------------------------------------

III. Demographic Characteristics

    A. Economic profile.
    1. Labor force and employment trends between 1980 and the 
present year. This will provide current year estimates and projected 
changes at the county level.
    Civilian Labor Force and Employment Trends and Forecasts, 
______________ County, 1980-19____ 

------------------------------------------------------------------------
                                                         19__\1\        
                                                  1990             19__ 
------------------------------------------------------------------------
Civilian Labor Force\2\........................                         
  Unemployment.................................                         
    Rate of Unemployment.......................                         
  Employment...................................                         
Change in Total Employment ....................                         
------------------------------------------------------------------------

Number-----------------------------------------------------------------

Percent

------------------------------------------------------------------------
                                                  Annual          Annual
                                          Total           Total         
------------------------------------------------------------------------
1980-1990...............................                                
1990-19__...............................                                
19__-19__ (2-year projection) ..........                                
------------------------------------------------------------------------
\1\Preliminary--based on monthly data through ________         
\2\Data based on place of residence.                                    
                                                                        
 Source:                                                                

    2. Employment data. In order to determine how employment affects 
the market area, it will be necessary to show the number of employed 
persons for a 3-year period up to the current year, the increase 
and/or decrease and the percentage of unemployed at the county 
level. The employment figures can be obtained from the State 
Employment Commission.

Example

County-----------------------------------------------------------------

------------------------------------------------------------------------
                                                            Unemployment
                  Year                    Number   Change        %      
------------------------------------------------------------------------
19__....................................                                
19__....................................                                
19__....................................                                
19__ (through current year).............                                
------------------------------------------------------------------------

Source

    3. Major employers. This section will contain information 
pertinent to an analysis of the economic stability of the town. The 
major employers within the town and market area, the product or 
service offered by each employer, location of employer, and year 
each employer was established are types of data FmHA will need to 
evaluate. It is also important to know if the larger employers 
intend to increase or decrease number of employees in the immediate 
future or if there have been any significant recent changes in 
number of employees.

Example

------------------------------------------------------------------------
                                                                 Year   
     Employer         Product/Service         Location       Established
                                                                        
------------------------------------------------------------------------
Washington Aircraft   Crop Dusting.....  Town..............      1957   
------------------------------------------------------------------------

    In addition, the study will include the number of employees and 
average weekly salary listed in the place of work employment data 
for the classification groups of manufacturing; construction; trade; 
services; transportation, communications, and utilities (TCU); 
finance, insurance, and real estate (FIRE); and government.
    4. Employment outside of county. The analyst will give the 
percentage of persons employed inside the county and driving times, 
if appropriate.

Source

    B. Demographic profile.
    1. Population. The analyst will need to show population changes 
between 1980 and 1990, the reasons for the changes, the current year 
estimate and projected change. This information will be provided for 
the town, the market area, and the county. Any change in the County 
subdivisions (CCD, Township, Election District, etc.) between census 
years will have to be explained. These are to be shown in numeric 
characters as well as percentages.

Example

------------------------------------------------------------------------
                                           Total               Annual   
             Year               ----------------------------------------
                                     No.      Change    %   Change    % 
------------------------------------------------------------------------
1980...........................                                         
1990...........................                                         
19__ (current estimate) .......                                         
------------------------------------------------------------------------
Projected: 19__ (2 years)                                               

    2. Age characteristics. 

------------------------------------------------------------------------
                        Town, 1980-1990            County, 1980-1990    
      Age        -------------------------------------------------------
                    1980      1990    Change    1980     1990     Change
------------------------------------------------------------------------
Under 18........                                                        
19-34...........                                                        
35-54...........                                                        
55-61...........                                                        
62-74...........                                                        
75-84...........                                                        
85+.............                                                        
------------------------------------------------------------------------

    3. Households. A breakdown by town, market area, and county for 
last 2 census years, a current year estimate and a projection to the 
year the housing would be built (24 months) will have to be 
illustrated so that household formations can be tracked. This data 
will tell us what portion of a housing demand is being created by an 
increase in numbers of new households. 

--------------------------------------------------------------------------------------------------------------------------------------------------------
                                                                                 In group                                                               
                   Year*                     ---------------------------------------------------------------------------------   Persons per household  
                                                     Population                  Quarters                  Households                                   
--------------------------------------------------------------------------------------------------------------------------------------------------------
1980........................................                                                                                                            
1990........................................                                                                                                            
19__ .......................................                                                                                                            
--------------------------------------------------------------------------------------------------------------------------------------------------------
Projected: 19__ (2 years)                                                                                                                               

    4. Households by Size/Type/Age of Members (elderly and 
congregate projects).

------------------------------------------------------------------------
                                                          Market        
                                                 -----------------------
                                                  Town   Area    County 
------------------------------------------------------------------------
Households with:                                                        
1 or more age 60 years and over.................                        
  1 person household............................                        
  2 or more persons (family)....................                        
  2 or more persons (nonfamily).................                        
1 or more age 65 and over.......................                        
  1 person household............................                        
  2 or more persons (family)....................                        
  2 or more persons (nonfamily).................                        
------------------------------------------------------------------------

    5. Household type and relationship--Persons 65+ (elderly and 
congregate projects). 

------------------------------------------------------------------------
                                                          Market        
                                                 -----------------------
                                                  Town   Area    County 
------------------------------------------------------------------------
Total...........................................                        
  In Households.................................                        
  In Family Households..........................                        
    Householder.................................                        
    Spouse......................................                        
    Other Relatives.............................                        
    Nonrelatives................................                        
  In Nonfamily Households.......................                        
    Male Householder............................                        
    Living Alone................................                        
    Not Living Alone............................                        
    Female Householder..........................                        
    Living Alone................................                        
    Not Living Alone............................                        
    Nonrelatives................................                        
  In Group Quarters.............................                        
    Institution (persons).......................                        
    Other Persons in Group Quarters ............                        
------------------------------------------------------------------------

    6. Households by tenure. This section is one of the more 
important aspects of the market analysis. This information will 
enable FmHA to more closely pinpoint the number of households which 
would comprise the target group of its evaluation. If the projected 
percentage of renters exceeds the historic percentage of renters, 
the analyst will have to explain why there is an increase. The 
information will be provided for town, market area, and county.

Example 

--------------------------------------------------------------------------------------------------------------------------------------------------------
                        Year                               Total households            Owner            Percent            Renter            Percent    
--------------------------------------------------------------------------------------------------------------------------------------------------------
1980................................................                                                                                                    
1990................................................                                                                                                    
Estimate: 19 __.....................................                                                                                                    
Projected: 19 __ (2 years) .........................                                                                                                    
--------------------------------------------------------------------------------------------------------------------------------------------------------

    7. Households by size. The study will provide number of 
households by household size for the town, market area, and county.
    8. Tenure by age. Tenure by age of householder for town, market 
area, and county (elderly and congregate projects). 

------------------------------------------------------------------------
                                             Owner     Renter     Total 
------------------------------------------------------------------------
55-64.....................................                              
65-74.....................................                              
75 years +................................                              
------------------------------------------------------------------------

    9. Households by income group. With the advent of Low Income 
Housing Tax Credits (LIHTC), we have found that more emphasis must 
be placed on analyzing persons whose incomes qualify for LIHTC. This 
means families who earn 60 percent or less of the median income as 
established by the U. S. Department of Housing and Urban Development 
(HUD). Therefore, feasibility for projects expecting to receive tax 
credits will also be based on the incomes required to support the 
tax credits. This could mean a level of incomes either slightly 
lower or higher than FmHA very low-incomes. For those tax credit 
units occupied by low-income families, the monthly gross rent cannot 
exceed 30 percent of the family income. Gross rent includes 
utilities, but excludes payments of rental assistance by Federal, 
State, and local entities. The applicant will be responsible for 
notifying FmHA and the market analyst of the amount of tax credits 
being requested, the income percentage on which the credits will be 
based, and the percentage of project units targeted for tax credit 
eligible persons. In those cases where less than 100 percent of the 
units will be designated for tax credit eligible persons, the 
incomes needed to support the non-LIHTC units will need to be 
analyzed. Income data will be shown for total and renter households. 
This information will be presented as follows: (It is recommended 
that decile distribution of incomes be obtained from HUD. Other 
sources are acceptable and must be identified.)
Incomes Needed to Support Proposed Rents + Utilities (without 
LIHTC): 

------------------------------------------------------------------------
    1-Bedroom          2-Bedroom         3-Bedroom          4-Bedroom   
------------------------------------------------------------------------
$______            $______            $______           $______         
------------------------------------------------------------------------

Number of Tax Credit Units Requested for Project:
----------------------------------------------------------------------
Percentage of Units to be Designated for Tax Credit Eligible 
Persons:
________    ______    ______    ______
Tax Credit Eligible Incomes: (based on 50% [  ] or 60% [  ] of 
income)
$______    $______    $______    $______
Tax Credit Eligible Rents:
$______    $______    $______    $______
Proposed Project Rents:
$______    $______    $______    $______

Town or Market Area 

----------------------------------------------------------------------------------------------------------------
                                                             All households              Renter households      
              Household income groups                -----------------------------------------------------------
                                                         Number         Percent        Number         Percent   
----------------------------------------------------------------------------------------------------------------
Less than $000......................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
    Total...........................................                                                            
    Median..........................................                                                            
Elderly Household Income Groups:                                                                                
Less than $.........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
    Total...........................................                                                            
----------------------------------------------------------------------------------------------------------------

    Incomes of those eligible to live in the proposed project, 
considering tax credits and availability of rental assistance (RA):
$000-$000
$000-$000


Source:

County 

----------------------------------------------------------------------------------------------------------------
                                                             All households              Renter households      
              Household income groups                -----------------------------------------------------------
                                                         Number         Percent        Number         Percent   
----------------------------------------------------------------------------------------------------------------
Less than $000......................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
    Total...........................................                                                            
    Median..........................................                                                            
Elderly Household Income Groups:                                                                                
Less than $.........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
$000-$000...........................................                                                            
    Total...........................................                                                            
----------------------------------------------------------------------------------------------------------------

    Incomes of those eligible to live in the proposed project, 
considering tax credits and availability of RA:
$000-$000
$000-$000

Source:

C. Housing supply profile

    1. Building permits issued for the last 10 years. The Housing 
Units Authorized by Building Permits and Public Contracts (C-40 
Construction Report), furnished by the Bureau of the Census, 
provides a list of permits issued in all reporting jurisdictions. 
This publication is printed monthly and annually. If available, the 
number of units which have been demolished over the last 5 years 
will be needed.

Example: 

--------------------------------------------------------------------------------------------------------------------------------------------------------
                                                    Town                                                             County                             
        Year         -----------------------------------------------------------------------------------------------------------------------------------
                          Single family         Multifamily              Demol.             Single family          MultiFamily             Demol.       
--------------------------------------------------------------------------------------------------------------------------------------------------------
19______............                                                                                                                                    
19______............                                                                                                                                    
19______............                                                                                                                                    
19______............                                                                                                                                    
    Through current                                                                                                                                     
     year.                                                                                                                                              
--------------------------------------------------------------------------------------------------------------------------------------------------------

    2. Housing stock. The study must include the number of units 
within the town and county (where available), both single family and 
multi-family, the number of mobile homes by tenure, along with the 
number of substandard units by tenure, based on the most recent 
census data. Occasionally, a situation will exist within a community 
where a number of detached single family homes are standing vacant. 
How this condition may affect the rental market must be evaluated 
and discussed.

Example:

Inventory Change Profile 

----------------------------------------------------------------------------------------------------------------
                                                                                     Mobile home                
                             Single family          Multifamily      -------------------------------------------
                                                                              Own                   Rent        
----------------------------------------------------------------------------------------------------------------
1980 Stock..............  ....................  ....................  ....................  ....................
1990 Stock..............  ....................  ....................  ....................  ....................
----------------------------------------------------------------------------------------------------------------


------------------------------------------------------------------------
                                                     Annual     Percent 
------------------------------------------------------------------------
Change in Number of Units.........................                      
------------------------------------------------------------------------

    3. Existing rental housing. The analyst must determine where the 
proposed project will fit into the present housing stock. To 
accomplish this, the analyst will survey the existing units and will 
discuss how they (a) would be comparable with the proposed project 
in overall appeal; (b) are less than desirable because of the age 
factor or upkeep; (c) are inconveniently located; (d) do not provide 
the appropriate bedroom mix for the community need, etc.
    4. Details of existing stock.
    a. Additional narrative which describes the rental stock and 
provides tenant characteristics may be included. The survey will 
include both subsidized and nonsubsidized rentals. In those 
communities containing too many rental properties to list, all 
subsidized and a representative number of conventional projects will 
be included. Those conventional projects which have rent levels 
comparable to the proposed project will be listed. Because elderly 
persons may reside in family designated projects, the analyst will 
need to list all existing units and not just the existing elderly 
units. Photographs of the comparables are required.
    b. The analyst will explore the availability of individual 
Section 8 certificates with the local housing authority since they 
can be used on any project to bring the existing rents into an 
affordable range. For instance, 10 to 15 available Section 8 
certificates in a community could have an influence on the 
determination for new units and the number should be reduced to 
correspond to this availability. However, before automatically 
reducing the number of proposed units to match the number of 
available Section 8 units, the reason the certificates are available 
must be explored, (e.g., owners of non-Government subsidized units 
will not accept the certificates). (The bedroom sizes which the 
certificates cover must match the prospective bedroom sizes in the 
proposed project bedroom mix.)
    c. The information needed in the survey must include the 
characteristics shown below. In conjunction with the survey, the 
analyst is expected to discuss the reasons for extended vacancies, 
either in individual developments or in the community in general. 
The data needed are:

Name of Project
No. of Units
Bedroom Mix
Amenities: (if available)
Drapes
Carpet
Type (i.e., family, elderly)
Year Built
Rent levels
Vacancies
Location
Central Cooling
Dishwasher
Garbage Disposal
TV Cable

IV. Housing demand forecasts.

    The analyst must give a projection of the housing needs for a 
specified forecast period. The information should include the 
following as a minimum: 

------------------------------------------------------------------------
                                            Town          Market area   
          Sources of demand          -----------------------------------
                                           Renter            Renter     
------------------------------------------------------------------------
New Households (from the most recent  __________        __________      
 census year plus 2-year projection).                                   
.20 of Persons Living in Substandard  +__________       +__________     
 Rental Units.                                                          
Plus Demolition of Rental Stock.....  +__________       +__________     
.20 of Persons Experiencing Rent      +__________       +__________     
 Overburden.                                                            
Plus Vacancy (.05 of New Household    +__________       +__________     
 Growth).                                                               
    Total Demand....................  __________        __________      
Number of Total Demand Determined     __________        __________      
 Income Eligible (tax credit                                            
 eligible, if applicable).                                              
Less Number of Units in Planning      -__________       -__________     
 Stage (FmHA/HUD) and Comparable                                        
 Rental Units.                                                          
    Net Demand......................  __________        __________      
------------------------------------------------------------------------

    If a penetration percentage is used in the study analysis, 
explain how that particular percentage was chosen.

Recommended Number By Unit Size:

One __________
Two __________
Three __________
Four __________

Names and positions of individuals in the community who provided 
information for the study:
----------------------------------------------------------------------
----------------------------------------------------------------------
----------------------------------------------------------------------
----------------------------------------------------------------------
    I affirm that I, or an individual under contract to my company, 
have made a physical inspection of the market area and that 
information has been used in the full assessment of the need and 
demand for new rental units. I understand that misrepresentation of 
this statement may result in denial of further participation in the 
FmHA Section 515 program.

----------------------------------------------------------------------
Market Analyst

    25. Exhibit A-9 of subpart E is amended in the introductory text 
of paragraph 9 by revising the words ``Statement of Budget and Cash 
Flow'' to read ``Multiple Family Housing Project Budget'' and by 
revising the exhibit heading and paragraphs 2 and 5 to read as 
follows:

Exhibit A-9 of Subpart E--Information To Be Submitted With Application 
for Rural Rental Housing (RRH) and Rural Cooperative Housing (RCH) 
Loans

* * * * *
    2. Updated cost estimates on Form FmHA 1924-13, ``Estimate and 
Certificate of Actual Cost,'' will be submitted by all applicants, 
along with the updated estimates of associated costs specified in 
Exhibit A-7 of this subpart.
* * * * *
    5. If more than 12 months have transpired since the applicant 
submitted the market analysis, the State Director may require that 
it be updated if he/she determines it necessary.
* * * * *
    26. Exhibit A-10 of subpart E is amended by adding paragraph II C 
to read as follows:

Exhibit A-10 of Subpart E--Administrative Process for Combining Farmers 
Home Administration (FmHA) Assistance With Low-Income Housing Tax 
Credits

* * * * *
    II * * *
    C. The State Director or designee will cooperate with the State 
Agency in the development of the Comprehensive Housing Affordability 
Stategy (CHAS) plan to ensure that, to the extent possible, resources 
available from FmHA are coordinated with the CHAS plan to maximize the 
use of housing funds in rural areas. This cooperation may include, but 
is not limited to, the sharing of Census data and priority point scores 
throughout the State, providing information on funding levels, 
preapplications and applications, and rural area designations made by 
FmHA.


Secs. 1944.222, 1944.231, 1944.235, 1944.246, Exhibit A-6  [Amended]

    27. 7 CFR chapter XVIII, part 1944, subpart E is amended by 
revising the words ``District Office'' to read ``servicing office'' in 
the following places:
    a. Section 1944.222 (a)
    b. Section 1944.231 (b), (c)(6), introductory text of (d), and 
(i)(1)(vi)
    c. Section 1944.235 (f)(1)
    d. Section 1944.246 (b)(3)
    e. Exhibit A-6, paragraph IV


Secs. 1944.235, 1994.236, 1944.239  [Amended]

    28. 7 CFR chapter XVIII, part 1944, subpart E is amended by 
revising the words ``district office'' to read ``servicing office'' in 
the following places:
    a. Section 1944.235 (e)(1)
    b. Section 1944.236 (e)(2)
    c. Section 1944.239 (introductory text)


Secs. 1944.205, 1944.212, 1944.215, 1944.222, 1944.231, 1944.232, 
1944.235, 1944.236, 1944.246, Exhibits A, A-6, and B  [Amended]

    29. 7 CFR chapter XVIII, part 1944, subpart E is amended by 
revising the words ``District Director'' to read ``servicing official'' 
in the following places:
    a. Section 1944.205, the definition of ``Dealer-contractor''
    b. Section 1944.212 (l)(1)
    c. Section 1944.215 (r)(6) (v) and (u)
    d. Section 1944.222 (g)
    e. Section 1944.231--the heading of (c), (c)(1)--3 times, (c)(3), 
(c)(4), introductory text of (c)(5)--2 times, (c)(6)--2 times, (c)(8), 
newly designated (e) (4) and (5), (f)(2), (i)(1)(i), (i)(1)(viii), 
(i)(5)(iv), (j)(3)--2 times
    f. Section 1944.232 (c)--2 times
    g. Section 1944.235 (c)(1)(v), introductory text of (c)(1)(vii), 
(c)(2)(ii), (d)--2 times, (e)(1), (e)(2), (f)(1), introductory text of 
(h), (h)(1)--2 times, (h)(2), and (h)(3)--2 times
    h. Section 1944.236 (d)
    i. Section 1944.246 (b)(2)(ii)
    j. Exhibit A--paragraphs II. A., II. B., III. C., the undesignated 
paragraph following paragraph III. C.--2 times, IV. A.--3 times, IV. B. 
1. b.--2 times, IV.B.6.a., IV.B.7.b., the introductory text of 
IV.B.8.b., IV.B.9.c., IV.B.12., the introductory text of IV.B.16.a., 
IV.B.22.--2 times, V. A.--2 times, V. C., V. D., VI. A. 1.
    k. Exhibit A-6, paragraph IV
    l. Exhibit B, at the end of the undesignated paragraph beginning 
``FmHA has required the applicant''.


Sec. 1944.231 and Exhibit A  [Amended]

    30. 7 CFR chapter XVIII, part 1944, subpart E is amended by 
revising the words ``District Director's'' to read ``servicing 
official's'' in the following places:
    a. Section 1944.231 (i)(1)(iv)
    b. Section 1944.231 (i)(1)(v)
    c. Section 1944.231 (k)(3)
    d. Exhibit A, paragraph III.A.

    Dated: January 19, 1994.
Bob Nash,
Under Secretary, Small Community and Rural Development.
[FR Doc. 94-3117 Filed 2-11-94; 8:45 am]
BILLING CODE 3410-07-U