[House Report 105-8]
[From the U.S. Government Publishing Office]
105th Congress Report
HOUSE OF REPRESENTATIVES
1st Session 105-8
_______________________________________________________________________
OROVILLE-TONASKET CLAIM SETTLEMENT AND CONVEYANCE ACT
_______
March 10, 1997.--Committed to the Committee of the Whole House on the
State of the Union and ordered to be printed
_______________________________________________________________________
Mr. Young of Alaska, from the Committee on Resources, submitted the
following
R E P O R T
together with
DISSENTING VIEWS
[To accompany H.R. 412]
[Including cost estimate of the Congressional Budget Office]
The Committee on Resources, to whom was referred the bill
(H.R. 412) to approve a settlement agreement between the Bureau
of Reclamation and the Oroville-Tonasket Irrigation District,
having considered the same, report favorably thereon with an
amendment and recommend that the bill as amended do pass.
The amendment is as follows:
Strike out all after the enacting clause and insert in lieu
thereof the following:
SECTION 1. SHORT TITLE.
This Act may be cited as the ``Oroville-Tonasket Claim Settlement and
Conveyance Act''.
SEC. 2. PURPOSES.
The purposes of this Act are to authorize the Secretary of the
Interior to implement the provisions of the negotiated Settlement
Agreement including conveyance of the Project Irrigation Works,
identified as not having national importance, to the District, and for
other purposes.
SEC. 3. DEFINITIONS.
As used in this Act:
(1) The term ``Secretary'' means the Secretary of the
Interior.
(2) The term ``Reclamation'' means the United States Bureau
of Reclamation.
(3) The term ``District'' or ``Oroville-Tonasket Irrigation
District'' means the project beneficiary organized and
operating under the laws of the State of Washington, which is
the operating and repayment entity for the Project.
(4) The term ``Project'' means the Oroville-Tonasket unit
extension, Okanogan-Similkameen division, Chief Joseph Dam
Project, Washington, constructed and rehabilitated by the
United States under the Act of September 28, 1976 (Public Law
94-423, 90 Stat. 1324), previously authorized and constructed
under the Act of October 9, 1962 (Public Law 87-762, 76 Stat.
761), under the Federal reclamation laws (including the Act of
June 17, 1902 (ch. 1093, 32 Stat. 388), and Acts supplementary
thereto or amendatory thereof).
(5) The term ``Project Irrigation Works'' means--
(A) those works actually in existence and described
in subarticle 3(a) of the Repayment Contract, excluding
Wildlife Mitigation Facilities, and depicted on the
maps held by the District and Reclamation, consisting
of the realty with improvements and real estate
interests;
(B) all equipment, parts, inventories, and tools
associated with the Project Irrigation Works realty and
improvements and currently in the District's
possession; and
(C) all third party agreements.
(6)(A) The term ``Basic Contract'' means Repayment Contract
No. 14-06-100-4442, dated December 26, 1964, as amended and
supplemented, between the United States and the District;
(B) the term ``Repayment Contract'' means Repayment Contract
No. 00-7-10-W0242, dated November 28, 1979, as amended and
supplemented, between the United States and the District; and
(C) the term ``third party agreements'' means existing
contractual duties, obligations, and responsibilities that
exist because of all leases, licenses, and easements with
third-parties related to the Project Irrigation Works, or the
lands or rights-of-way for the Project Irrigation Works, but
excepting power arrangements with the Bonneville Power
Administration.
(7) The term ``Wildlife Mitigation Facilities'' means--
(A) land, improvements, or easements, or any
combination thereof, secured for access to such lands,
acquired by the United States under the Fish and
Wildlife Coordination Act (16 U.S.C. 661-667e); and
(B) all third party agreements associated with the
land, improvements, or easements referred to in
subparagraph (A).
(8) The term ``Indian Trust Lands'' means approximately 61
acres of lands identified on land classification maps on file
with the District and Reclamation beneficially owned by the
Confederated Tribes of the Colville Reservation (Colville
Tribes) or by individual Indians, and held in trust by the
United States for the benefit of the Colville Tribes in
accordance with the Executive Order of April 9, 1872.
(9) The term ``Settlement Agreement'' means the Agreement
made and entered on April 15, 1996, between the United States
of America acting through the Regional Director, Pacific
Northwest Region, Bureau of Reclamation, and the Oroville-
Tonasket Irrigation District.
(10) The term ``operations and maintenance'' means normal and
reasonable care, control, operation, repair, replacement, and
maintenance.
SEC. 4. AGREEMENT AUTHORIZATION.
The Settlement Agreement is approved and the Secretary of the
Interior is authorized to conduct all necessary and appropriate
investigations, studies, and required Federal actions to implement the
Settlement Agreement.
SEC. 5. CONSIDERATION AND SATISFACTION OF OUTSTANDING OBLIGATIONS.
(a) Consideration to United States.--Consideration by the District to
the United States in accordance with the Settlement Agreement approved
by this Act shall be--
(1) payment of $350,000 by the District to the United States;
(2) assumption by the District of full liability and
responsibility and release of the United States of all further
responsibility, obligations, and liability for removing
irrigation facilities constructed and rehabilitated by the
United States under the Act of October 9, 1962 (Public Law 87-
762, 76 Stat. 761), or referenced in section 201 of the Act of
September 28, 1976 (Public Law 94-423, 90 Stat. 1324), and
identified in Article 3(a)(8) of the Repayment Contract;
(3) assumption by the District of sole and absolute
responsibility for the operations and maintenance of the
Project Irrigation Works;
(4) release and discharge by the District as to the United
States from all past and future claims, whether now known or
unknown, arising from or in any way related to the Project,
including any arising from the Project Irrigation Works
constructed pursuant to the 1964 Basic Contract or the 1979
Repayment Contract;
(5) assumption by the District of full responsibility to
indemnify and defend the United States against any third party
claims associated with any aspect of the Project, except for
that claim known as the Grillo Claim, government contractor
construction claims accruing at any time, and any other suits
or claims filed as of the date of the Settlement Agreement; and
(6) continued obligation by the District to deliver water to
and provide for operations and maintenance of the Wildlife
Mitigation Facilities at its own expense in accordance with the
Settlement Agreement.
(b) Responsibilities of United States.--In return the United States
shall--
(1) release and discharge the District's obligation,
including any delinquent or accrued payments, or assessments of
any nature under the 1979 Repayment Contract, including the
unpaid obligation of the 1964 Basic Contract;
(2) transfer title of the Project Irrigation Works to the
District;
(3) assign to the District all third party agreements
associated with the Project Irrigation Works;
(4) continue power deliveries provided under section 6 of
this Act; and
(5) assume full responsibility to indemnify and defend the
District against any claim known as the Grillo Claim,
government contractor construction claims accruing at any time,
and any other suits or claims filed against the United States
as of the date of the Settlement Agreement.
(c) Project Construction Costs.--The transfer of title authorized by
this Act shall not affect the timing or amount of the obligation of the
Bonneville Power Administration for the repayment of construction costs
incurred by the Federal government under section 202 of the Act of
September 28, 1976 (90 Stat. 1324, 1326) that the Secretary of the
Interior has determined to be beyond the ability of the irrigators to
pay. The obligation shall remain charged to, and be returned to the
Reclamation Fund as provided for in section 2 of the Act of June 14,
1966 (80 Stat. 200) as amended by section 6 of the Act of September 7,
1966 (80 Stat. 707, 714).
SEC. 6. POWER.
Nothing in this Act shall be construed as having any affect on power
arrangements under Public Law 94-423 (90 Stat. 1324). The United States
shall continue to provide to the District power and energy for
irrigation water pumping for the Project, including Dairy Point Pumping
Plant. However, the amount and term of reserved power shall not exceed,
respectively--
(1) 27,100,000 kilowatt hours per year; and
(2) 50 years commencing October 18, 1990.
The rate that the District shall pay the Secretary for such reserved
power shall continue to reflect full recovery of Bonneville Power
Administration transmission costs.
SEC. 7. CONVEYANCE.
(a) Conveyance of Interests of United States.--Subject to valid
existing rights, the Secretary is authorized to convey all right,
title, and interest, without warranties, of the United States in and to
all Project Irrigation Works to the District. In the event a
significant cultural resource or hazardous waste site is identified,
the Secretary is authorized to defer or delay transfer of title to any
parcel until required Federal action is completed.
(b) Retention of Title to Wildlife Mitigation Facilities.--The
Secretary will retain title to the Wildlife Mitigation Facilities. The
District shall remain obligated to deliver water to and provide for the
operations and maintenance of the Wildlife Mitigation Facilities at its
own expense in accordance with the Settlement Agreement.
(c) Reservation.--The transfer of rights and interests pursuant to
subsection (a) shall reserve to the United States all oil, gas, and
other mineral deposits and a perpetual right to existing public access
open to public fishing,hunting, and other outdoor recreation purposes,
and such other existing public uses.
SEC. 8. REPAYMENT CONTRACT.
Upon conveyance of title to the Project Irrigation Works
notwithstanding any parcels delayed in accordance with section 7(a),
the 1964 Basic Contract, and the 1979 Repayment Contract between the
District and Reclamation, shall be terminated and of no further force
or effect.
SEC. 9. INDIAN TRUST RESPONSIBILITIES.
The District shall remain obligated to deliver water under
appropriate water service contracts to Indian Trust Lands upon request
from the owners or lessees of such land.
SEC. 10. LIABILITY.
Upon completion of the conveyance of Project Irrigation Works under
this Act, the District shall--
(1) be liable for all acts or omissions relating to the
operation and use of the Project Irrigation Works that occur
before or after the conveyance except for the Grillo Claim,
government contractor construction claims accruing at any time,
and any other suits or claims filed as of the date of the
Settlement Agreement;
(2) absolve the United States and its officers and agents of
responsibility and liability for the design and construction
including latent defects associated with the Project; and
(3) assume responsibility to indemnify and defend the United
States against all claims whether now known or unknown and
including those of third party claims associated with, arising
from, or in any way related to, the Project except for the
Grillo Claim, government contractor construction claims
accruing at any time, and any other suits or claims filed as of
the date of the Settlement Agreement.
SEC. 11. CERTAIN ACTS NOT APPLICABLE AND TERMINATION OF MANDATES.
(a) Reclamation Laws.--All mandates imposed by the Reclamation Act of
1902, and all Acts supplementary thereto or amendatory thereof,
including the Reclamation Reform Act of 1982, upon the Project
Irrigation Works shall be terminated upon the completion of the
transfers as provided by this Act and the Settlement Agreement.
(b) Relationship to Other Laws.--The transfer of title authorized by
this Act shall not--
(1) be subject to the provisions of chapter 5 of title 5,
United States Code (commonly known as the ``Administrative
Procedure Act''); or
(2) be considered a disposal of surplus property under the
Federal Property and Administrative Services Act of 1949 (40
U.S.C. 471 et seq.) and the Surplus Property Act of 1944 (50
U.S.C. App. 1601 et seq.).
(c) Deauthorization.--Effective upon transfer of title to the
District under this Act, that portion of the Oroville-Tonasket Unit
Extension, Okanogan-Similkameen Division, Chief Joseph Dam Project,
Washington, referred to in section 7(a) as the Project Irrigation Works
is hereby deauthorized. After transfer of title, the District shall not
be entitled to receive any further Reclamation benefits pursuant to the
Reclamation Act of June 17, 1902, and Act supplementary thereto or
amendatory thereof.
PURPOSE OF THE BILL
The purpose of H.R. 412 is to approve a settlement
agreement between the Bureau of Reclamation, an agency of the
Department of the Interior, and the Oroville-Tonasket
Irrigation District of Washington.
BACKGROUND AND NEED FOR LEGISLATION
The Oroville-Tonasket Unit Extension Project is located in
north-central Washington, near the towns of Oroville and
Tonasket. The Project begins at the Canadian border north of
Oroville, Washington, and extends south on both sides of the
Okanogan River about 26 miles, providing irrigation water to
about 10,000 acres.
The original canal and the flume system serving the
Oroville-Tonasket Irrigation District were built in increments
by the District starting in the early 1900s. The old Works
Progress Administration (WPA) conducted a major rehabilitation
of the works between 1940 and 1942. At that time, the WPA
renewed and replaced sections of the wood flume, earth sections
of the delivery system were concrete lined, and the WPA
constructed some tunnels and concrete flumes.
In 1952, legislation was enacted that provided for studying
of the prospects of irrigation near Chief Joseph Dam. Based
upon these studies, the Congress approved legislation in 1962
(Public Law 87-762) authorizing the rehabilitation of the
original Project system and the construction of new works. This
provided an additional and supplemental water supply to 8,450
acres of the Project. In 1964, the District and the Bureau of
Reclamation entered into a repayment contract for
rehabilitation of the irrigation project. Work under this
contract included rehabilitation of the headworks structure,
reaches of the main canal, the Upper Okanogan siphon, and
installation of three auxiliary pumping plants along the
Okanogan River. Construction was completed in 1968.
Even while this rehabilitation work was being conducted,
the distribution system continued to deteriorate to the point
that failure of the system was imminent. This prompted the
District to request and Congress to enact legislation in 1966
directing the Bureau of Reclamation to undertake a feasibility
investigation of the Project. In 1976, Congress authorized
Reclamation to construct the Oroville-Tonasket Unit Extension
under Public Law 94-423, the Reclamation Authorizations Act of
1976. The Oroville-Tonasket Unit Extension was to be
constructed substantially in accordance with the feasibility
report, and consists of a pressurized pipe irrigation
distribution system and enhancement of fish resources. The
District entered into a repayment contract with Reclamation for
the work in 1979, and construction began in 1980.
With the initial operation of the Project in 1984, problems
were encountered with the inability of the project facilities
to cope with substantial amounts of silt in the Okanogan River,
and reauthorization was sought to increase the cost ceiling to
modify some of the pumping plants and reduce the silt entering
the irrigation system. Congressional reauthorization was
provided in 1987, and the cost ceiling was increased by about
$17.5 million, to $88 million.
The District was notified that the project was
substantially complete in 1990, which usually initiates
repayment under federal reclamation laws. The District's first
annual payment was dueJune 15, 1991. However, the District
disputes the project's substantial completion and has refused to
initiate repayment.
The District alleges that the irrigation system still does
not work as projected and that the annual operation and
maintenance costs are much higher than the Bureau of
Reclamation projected in the design phase. The District
unsuccessfully sought legislative relief from its repayment
obligations in 1993. In 1994, the District filed a lawsuit with
the Court of Federal Claims (Fed.Cl. No. 94-779C). The
complaint sought damages in excess of $44 million for alleged
contract breaches; necessary remedial construction; and
unfinished contractual obligations for which Reclamation
allegedly remains responsible. The District also sought be to
relieved of its repayment obligation to the United States in an
amount of at least $12.9 million. The complaint and the United
States' counterclaim were dismissed in 1995, without prejudice,
upon the determination that the court lacked jurisdiction
without a Contracting Officer's Decision pursuant to the
Contract Disputes Act.
Therefore, in April 1995, the District submitted a claim
under the Contract Disputes Act seeking $51 million in damages,
recision of its $13 million repayment obligation, and a
reduction of and a cap on power rates. The Contract Disputes
Act and the Bureau of Reclamation's own policies promote
negotiated settlements, so Reclamation considered various
options to litigating the disputed claim. An agreement to
negotiate was signed by the parties on December 1, 1995, which
included a provision giving the parties until April 1, 1996, to
reach a negotiated settlement. Otherwise, a Contracting
Officer's Decision would be issued unilaterally by the Bureau
of Reclamation with respect to the disputed claim.
On December 26, 1995, the parties executed a conceptual
agreement which defined the broad areas of agreement. The
parties reached a settlement agreement on April 1, 1996, and
executed the settlement agreement on April 15, 1996. The
Settlement Agreement includes transfer of the title to the
Project Irrigation Works to the District. The United States
will also be relieved of financial liability for needed pipe
repairs on the Project, estimated to cost around $14 million.
Although this action is independent of the Bureau of
Reclamation's Title Transfer Initiative, Reclamation officials
have stated that the asset valuation was calculated pursuant to
procedures in that initiative.
Under the settlement agreement, the District agrees to:
release and discharge all past and future claims against the
United States associated with the Project; assume full
responsibility to indemnify and defend the United States
against any third-party claims associated with the Project;
makes a cash payment of $350,000 to the United States (this
condition has been met); and release the United States from its
obligation to remove existing dilapidated facilities.
The United States, under the terms of the settlement
agreement, agrees to: release and discharge the District's
construction charge obligation under the 1979 Repayment
Contract; limit power for irrigation water pumping not to
exceed 27.1 million kilowatt-hours per year for 50 years from
October 18, 1990; and transfer title to the Project Irrigation
Works to the District at no additional cost to the District.
With respect to the power agreement, it should be noted that
Public Law 94-423 authorized power to be made available to the
District without limits on quantity and in perpetuity.
The responsibilities for the protection of the cultural and
historical archaeological sites are being defined through a
separate agreement that has been negotiated between the
Confederated Tribes of the Colville Reservation, the District,
and the Bureau of Reclamation.
During the Committee markup, there was opposition expressed
to the discharge of the District's repayment obligation.
However, the Committee agreed with the position of the federal
negotiators, and with the Administration on this issue. While
federal negotiators did not recognize the validity of all of
the $51 million in claims filed by the District, they did
recognize the legitimacy of claims totaling slightly more than
the present value of the District's $13.3 million repayment
obligation, which is payable over the next 45 years. At the
time of the negotiations, the present value of this revenue
stream to the United States was estimated at $4.2 million. This
was calculated using 6.71 percent, the average 30-year Treasury
rate in August and September 1995, when the calculations were
performed.
It is the understanding of the Committee regarding this
legislation that the amount of Oroville-Tonasket Project
irrigation assistance that the Bonneville Power Administration
will repay is not expected to exceed $75 million, and that the
repayment is now scheduled to be made in the year 2042.
The Committee further notes that the settlement terms
approved in H.R. 412 were based on negotiations to resolve
litigation over the Oroville-Tonasket Unit. While the Committee
has approved the terms for transferring the project to the
Oroville-Tonasket Irrigation District, H.R. 412 should not be
regarded as Congressional ratification of any of the judicial
decisions underlying the settlement negotiations. In
particular, the Committee has not approved the court order in
Oroville-Tonasket Irrigation District v. United States holding
that the Contract Disputes Act should govern disputes of this
kind with the Bureau of Reclamation. The Committee finds that
decision troubling, and possibly contrary to the underlying
purposes of the Contract Disputes Act.
H.R. 412 also should not be regarded as a precedent for
legislative action to transfer Bureau of Reclamation facilities
at other projects. The litigation problems surrounding the
transfer of the Oroville-Tonasket Unit and continued provision
of power at low project power rates are unique. While the
Committee will consider transferring other Reclamation
facilities to local project beneficiaries under appropriate
circumstances, the terms of this transfer will not serve as
precedent for future transfers.
Similar legislation, H.R. 3777, was introduced by
Congressman Richard ``Doc'' Hastings (R-WA) in the 104th
Congress. H.R. 3777 was the subject of a legislative hearing in
the Subcommittee on Water and Power Resources on September 26,
1996. At that time, the Administration took no position on the
bill. However, on March 3, 1997, Chairman Don Young of the
Committee on Resources received a letter from the Commissioner
of Reclamation stating that the Administration could only
support H.R. 412 if certain specified amendments were adopted.
All of those amendments were adopted by the Committee during
consideration of the bill.
COMMITTEE ACTION
H.R. 412 was introduced on January 9, 1997, by Congressman
Richard ``Doc'' Hastings (R-WA). The bill was referred to the
Committee on Resources, and within the Committee to the
Subcommittee on Water and Power. On March 5, 1997, the Full
Committee met to consider H.R. 412, which was discharged from
the Subcommittee by unanimous consent. Congressman John T.
Doolittle offered an en bloc amendment to: stipulate that the
transfer of title does not affect the obligation of the power
customers for construction costs incurred that have been
determined to be beyond the ability of the irrigators to pay;
stipulate that the electric transmission rate paid by the
District will continue to reflect full cost recovery;
deauthorize that portion of the Oroville-Tonasket Unit
Extension referred to as the Project Irrigation Works as a
federal reclamation project; and to make several technical
corrections to the bill as introduced. The amendment was
adopted by voice vote. The bill, as amended, was then ordered
favorably reported to the House of Representatives by voice
vote.
COMMITTEE OVERSIGHT FINDINGS AND RECOMMENDATIONS
With respect to the requirements of clause 2(l)(3) of Rule
XI of the Rules of the House of Representatives, and clause
2(b)(1) of Rule X of the Rules of the House of Representatives,
the Committee on Resources' oversight findings and
recommendations are reflected in the body of this report.
CONSTITUTIONAL AUTHORITY STATEMENT
Article I, section 8 and Article IV, section 3 of the
Constitution of the United States grants Congress the authority
to enact H.R. 412.
COST OF THE LEGISLATION
Clause 7(a) of Rule XIII of the Rules of the House of
Representatives requires an estimate and a comparison by the
Committee of the costs which would be incurred in carrying out
H.R. 412. However, clause 7(d) of that Rule provides that this
requirement does not apply when the Committee has included in
its report a timely submitted cost estimate of the bill
prepared by the Director of the Congressional Budget Office
under section 403 of the Congressional Budget Act of 1974.
COMPLIANCE WITH HOUSE RULE XI
1. With respect to the requirement of clause 2(l)(3)(B) of
Rule XI of the Rules of the House of Representatives and
section 308(a) of the Congressional Budget Act of 1974, H.R.
412 does not contain any new budget authority, credit
authority, or an increase or decrease in revenues or tax
expenditures. Enactment of H.R. 412 could affect direct
spending, as described in the Congressional Budget Office cost
estimate contained in this report.
2. With respect to the requirement of clause 2(l)(3)(D) of
Rule XI of the Rules of the House of Representatives, the
Committee has received no report of oversight findings and
recommendations from the Committee on Government Reform and
Oversight on the subject of H.R. 412.
3. With respect to the requirement of clause 2(l)(3)(C) of
Rule XI of the Rules of the House of Representatives and
section 403 of the Congressional Budget Act of 1974, the
Committee has received the following cost estimate for H.R. 412
from the Director of the Congressional Budget Office.
CONGRESSIONAL BUDGET OFFICE COST ESTIMATE
U.S. Congress,
Congressional Budget Office,
Washington, DC, March 7, 1997.
Hon. Don Young,
Chairman, Committee on Resources,
House of Representatives, Washington, DC.
Dear Mr. Chairman: The Congressional Budget Office has
prepared the enclosed cost estimate for H.R. 412, the Oroville-
Tonasket Claim Settlement and Conveyance Act.
If you wish further details on this estimate, we will be
pleased to provide them. The CBO staff contact is Gary Brown.
Sincerely,
Paul Van de Water
(For June E. O'Neill, Director).
Enclosure.
Summary
H.R. 412 would approve a Settlement Agreement between the
United States Bureau of Reclamation (the Bureau) and the
Oroville-Tonasket Irrigation District (the District). The
agreement would settle litigation over disputes arising from
the construction of the Oroville-Tonasket Unit Extension, an
irrigation delivery unit. Under the Settlement Agreement, the
District would release and discharge all past and future claims
against the United States associated with the project, make a
cash payment of $350,000 to the United States (this condition
has already been met), and release the United States from its
obligation to remove existing dilapidated facilities. In
exchange, the Secretary of the Interior would release and
discharge the District's annual construction charge obligation
of roughly $300,000 under the 1979 Repayment Contract, transfer
title to the irrigation works to the District at no additional
cost to the District, and continue to provide power for the
pumping of irrigation water.
CBO expects that the federal government would probably save
money if this bill were enacted. However, we have no clear
basis for estimating the amount of such savings because they
would result from the release of the United States from future
legal claims against it by the District. CBO cannot estimate
the amount or timing of any potential judgments that might
occur if H.R. 412 is not enacted.
Because enacting the bill could affect direct spending,
pay-as-you-go procedures would apply. The legislation does not
contain any intergovernmental or private-sector mandates as
defined in the Unfunded Mandates Reform Act of 1995.
Estimated cost to the Federal Government
Direct spending
Enacting the legislation would settle claims pending
against the United States under the Contract Disputes Act.
Thus, the bill would allow the United States to avoid future
costs that could result from claims brought against it by the
Oroville-Tonasket Irrigation District. The District alleges
that the irrigation system does not work as anticipated and
that the annual operation and maintenance costs are much higher
than the Bureau of Reclamation projected in the design phase of
the project. The potential liability of the United States under
pending claims exceeds $51 million, but CBO cannot predict the
outcome of court proceedings of future negotiations that might
occur if the claims are not dropped. Any payments that might be
made under current law would be likely to occur after 1997.
Other provisions of the Settlement Agreement would have no
budgetary impact. Discharging the district of its obligation to
repay the cost of the Oroville-Tonasket Unit Extension would
not result in a loss of receipts that would otherwise have
accrued to the United States. The District has refused to repay
this cost since 1991, the first year in which repayment was
required, and is unlikely to begin repaying with or without the
proposed Settlement Agreement or in the absence of successful
legal action on the part of the United States. The District has
already made the separate $350,000 payment to the United States
that would be required under the agreement. Finally, the
agreement provides for the Secretary of the Interior to
continue providing power for irrigation pumping, just as he
would under current law.
For purposes of this estimate, CBO assumes that the
legislation will be enacted before April 15, 1997, the date on
which the District will proceed with litigation if the
Settlement Agreement has not been approved. The statute of
limitations for pursuing a legal claim expires in June of 1997.
Spending subject to appropriation
Based on information provided by the Bureau, CBO expects
that enacting the bill would not have a significant impact on
discretionary spending. The cost of transferring title to the
facility would be less than $500,000. Enacting the bill would
release the Bureau from certain obligations and expenses,
including the cost of removing dilapidated facilities from the
property to be transferred, likely legal fees, and annual
contract administration costs, but CBO estimates that
eliminating these costs would save less than $500,000 each
year.
Pay-as-you-go considerations
Section 252 of the Balanced Budget and Emergency Deficit
Control Act of 1985 sets up pay-as-you-go procedures for
legislation affecting direct spending or receipts through 1998.
CBO estimates that enacting H.R. 412 could affect direct
spending, but it is unclear whether direct spending would be
affected by 1998, if ever. CBO estimates that there would be no
effect on 1997 spending and that any potential effect on 1998
spending would be a savings relative to current law because
enacting H.R. 412 would eliminate the possibility of judgments
against the United States. CBO cannot predict the likelihood or
the timing of any judgment payments that might occur if H.R.
412 is not enacted.
Estimated impact on State, local, and tribal governments
H.R. 412 contains no intergovernmental mandates as defined
in the Unfunded Mandates Reform Act of 1995 (Public Law 104-4),
and would impose no costs on state, local, or tribal
governments. Any costs resulting from the Settlement Agreement
covered by this bill would be incurred voluntarily by the
District as a party to the agreement. The obligations of the
District and of the United States under this agreement are
discussed in detail in other sections of this estimate.
In addition to releasing the United States from future and
pending legal claims, the District has agreed to make (and has
already made) a cash payment to the United States and to assume
responsibility for removing dilapidated facilities. We estimate
that the cost of this latter obligation would be about
$300,000.
Estimated impact on the private sector
The bill would impose no new private-sector mandates as
defined in Public Law 104-4.
Estimate prepared by: Federal cost: Gary Brown; impact on
State, local, and tribal governments: Marjorie Miller; and
impact on the private sector: Lesley Frymeir.
Estimated approved by: Robert A. Sunshine, Deputy Assistant
Director for Budget Analysis.
compliance with public law 104-4
H.R. 412 contains no unfunded mandates.
changes in existing law
If enacted, H.R. 412 would make no changes to existing law.
DISSENTING VIEWS
The Oroville-Tonasket Unit of the Bureau of Reclamation's
Chief Joseph Dam project was completed in 1990. The local
Oroville-Tonasket Irrigation District (OTID) had entered into a
contract with the Bureau to receive irrigation water and repay
a portion of the project costs--over 80% of the irrigation
repayment costs would actually be paid by Northwest power
users, because the Bureau concluded that the entire project
cost exceeded the irrigators' ``ability to pay'' under
Reclamation law. When the project was completed, OTID became
obligated to begin repayment under its contract. But OTID
refused to pay. The district cited continuing problems with
siltation and project operations, some of which had already
been addressed in project modifications. The Bureau continued
to deliver water despite the district's failure to pay, and
interest accumulated on the mounting debt.
OTID was dissatisfied with the Bureau's performance, and
brought suit in the Court of Federal Claims. The court
concluded that the dispute should be handled under the
procedures specified in the Contract Disputes Act, and
dismissed the case without prejudice while the parties pursued
that process. Eventually, OTID signed a settlement agreement
with the regional director of the Bureau of Reclamation, which
would give OTID the project works for free and ensure OTID
another 45 years of cheap power supplies from federal power
facilities for operating the project. These settlement terms
exceeded the authority of the Bureau's regional director,
however, so he committed to try to obtain congressional
approval for the project transfer.
Despite the claims made by OTID regarding problems with the
operation of the Oroville-Tonasket Unit, we must oppose H.R.
412's free transfer of the project to OTID. If the Congress had
been given an opportunity to address the project's problems and
work out a solution with the irrigation district, we might well
have found a way to correct the deficiencies while assuring
reasonable project repayment. Instead, we have been presented
with a proposal to hand over the project to OTID at no cost,
forgiving over $1 million in past-due bills and a $14 million
repayment obligation, and providing another 45 years of cheap
power for project operations. This proposal has been presented
on a take-it-or-leave-it basis; we choose to leave it.
In the past, this Committee and the Congress on occasion
have provided relief to Bureau of Reclamation water users whose
projects have proved defective. For example, in 1992, we passed
legislation forgiving 50% of the costs of replacing defective
siphons installed on the Central Arizona Project. If OTID had
made its case in the Committee for forgiving some of the
project costs, or for federally financed repairs, we would have
been more receptive than we can be to the present legislation.
Instead, OTID decided to litigate, and now asks Congress to
step into the middle of the judicial process and ratify a
settlement that reduces their capital cost repayment obligation
to nothing. Over 80% of the project costs will be paid by power
customers in the Northwest region, to the tune of $73 million.
OTID has refused to pay its water bills for the last five
years, and thus has paid nothing toward project repayment. Now,
OTID wants taxpayers to give away the entire project for
nothing: the power users will pay 80%, the taxpayers will pay
20%, and the irrigators who actually use the project will pay
zero. This deal is simply too good.
Neither OTID nor anyone else can assert that the project is
worthless. If it were, OTID would hardly be seeking its
transfer to the district. In fact, OTID has received and will
continue to receive substantial benefits from the project for
decades to come. The project has delivered water for the last 5
years, and the irrigation district is planning on using it for
at least another 45 years.
In addition, OTID will continue to profit from a reliable
water supply and cheap power provided by the project throughout
that period. We cannot justify giving away such a valuable
capital asset constructed with the taxpayers' money.
This bill also fails the procedural requirements of the
House of Representatives, because it will violate the ``Pay As
You Go'' requirements of the Budget Act. Under this bill, the
Treasury will forego annual payments due from OTID, and receive
nothing in return. Thus, the bill will contribute to the annual
budget deficit in each of the next five years, and beyond.
For all of these reasons, we dissent from the Committee's
decision to report H.R. 412 as amended. We do agree with
amendments offered by the majority that will ensure that the
power users' portion of the repayment obligation will continue
to be repaid. We also agree strongly with language in the full
Committee report that expresses the view that this bill should
not be regarded as a precedent for Bureau of Reclamation
transfers generally, or as a ratification of judicial decisions
in OTID's litigation.
George Miller.
Ed Markey.
Peter DeFazio.
Ron Kind.
Sam Farr.
Maurice Hinchey.