[Title 48 CFR ]
[Code of Federal Regulations (annual edition) - October 1, 2001 Edition]
[From the U.S. Government Printing Office]


[[Page i]]
          

          48
          Chapters 3 to 6
          Revised as of October 1, 2001

          Federal Acquisition Regulations System





          Containing a codification of documents 
          of general applicability and future effect

          As of October 1, 2001

          With Ancillaries

          Published by
          Office of the Federal Register
          National Archives and Records
          Administration

          A Special Edition of the Federal Register


                                      
[[Page ii]]



                     U.S. GOVERNMENT PRINTING OFFICE
                            WASHINGTON : 2001



 For sale by the Superintendent of Documents, U.S. Government Printing Office
  Internet: bookstore.gpo.gov Phone: toll free (866) 512-1800; DC area 
                              (202) 512-1800
      Fax: (202) 512-2250 Mail: Stop SSOP, Washington, DC 20402-0001


[[Page iii]]


                            Table of Contents



                                                                    Page
  Explanation.................................................       v

  Title 48:
          Chapter 3--Health and Human Services                       3
          Chapter 4--Department of Agriculture                      91
          Chapter 5--General Services Administration               157
          Chapter 6--Department of State                           285
  Finding Aids:
      Table of CFR Titles and Chapters........................     359
      Alphabetical List of Agencies Appearing in the CFR......     377
      List of CFR Sections Affected...........................     387


      
[[Page iv]]

                     ----------------------------

                     Cite this Code:  CFR
                     To cite the regulations in 
                       this volume use title, 
                       part and section number. 
                       Thus, 48 CFR 301.101 
                       refers to title 48, part 
                       301, section 101.

                     ----------------------------

[[Page v]]

                               EXPLANATION

    The Code of Federal Regulations is a codification of the general and 
permanent rules published in the Federal Register by the Executive 
departments and agencies of the Federal Government. The Code is divided 
into 50 titles which represent broad areas subject to Federal 
regulation. Each title is divided into chapters which usually bear the 
name of the issuing agency. Each chapter is further subdivided into 
parts covering specific regulatory areas.
    Each volume of the Code is revised at least once each calendar year 
and issued on a quarterly basis approximately as follows:

Title 1 through Title 16.................................as of January 1
Title 17 through Title 27..................................as of April 1
Title 28 through Title 41...................................as of July 1
Title 42 through Title 50................................as of October 1

    The appropriate revision date is printed on the cover of each 
volume.

LEGAL STATUS

    The contents of the Federal Register are required to be judicially 
noticed (44 U.S.C. 1507). The Code of Federal Regulations is prima facie 
evidence of the text of the original documents (44 U.S.C. 1510).

HOW TO USE THE CODE OF FEDERAL REGULATIONS

    The Code of Federal Regulations is kept up to date by the individual 
issues of the Federal Register. These two publications must be used 
together to determine the latest version of any given rule.
    To determine whether a Code volume has been amended since its 
revision date (in this case, October 1, 2001), consult the ``List of CFR 
Sections Affected (LSA),'' which is issued monthly, and the ``Cumulative 
List of Parts Affected,'' which appears in the Reader Aids section of 
the daily Federal Register. These two lists will identify the Federal 
Register page number of the latest amendment of any given rule.

EFFECTIVE AND EXPIRATION DATES

    Each volume of the Code contains amendments published in the Federal 
Register since the last revision of that volume of the Code. Source 
citations for the regulations are referred to by volume number and page 
number of the Federal Register and date of publication. Publication 
dates and effective dates are usually not the same and care must be 
exercised by the user in determining the actual effective date. In 
instances where the effective date is beyond the cut-off date for the 
Code a note has been inserted to reflect the future effective date. In 
those instances where a regulation published in the Federal Register 
states a date certain for expiration, an appropriate note will be 
inserted following the text.

OMB CONTROL NUMBERS

    The Paperwork Reduction Act of 1980 (Pub. L. 96-511) requires 
Federal agencies to display an OMB control number with their information 
collection request. 

[[Page vi]]

Many agencies have begun publishing numerous OMB 
control numbers as amendments to existing regulations in the CFR. These 
OMB numbers are placed as close as possible to the applicable 
recordkeeping or reporting requirements.

OBSOLETE PROVISIONS

    Provisions that become obsolete before the revision date stated on 
the cover of each volume are not carried. Code users may find the text 
of provisions in effect on a given date in the past by using the 
appropriate numerical list of sections affected. For the period before 
January 1, 1986, consult either the List of CFR Sections Affected, 1949-
1963, 1964-1972, or 1973-1985, published in seven separate volumes. For 
the period beginning January 1, 1986, a ``List of CFR Sections 
Affected'' is published at the end of each CFR volume.

CFR INDEXES AND TABULAR GUIDES

    A subject index to the Code of Federal Regulations is contained in a 
separate volume, revised annually as of January 1, entitled CFR Index 
and Finding Aids. This volume contains the Parallel Table of Statutory 
Authorities and Agency Rules (Table I). A list of CFR titles, chapters, 
and parts and an alphabetical list of agencies publishing in the CFR are 
also included in this volume.
    An index to the text of ``Title 3--The President'' is carried within 
that volume.
    The Federal Register Index is issued monthly in cumulative form. 
This index is based on a consolidation of the ``Contents'' entries in 
the daily Federal Register.
    A List of CFR Sections Affected (LSA) is published monthly, keyed to 
the revision dates of the 50 CFR titles.

REPUBLICATION OF MATERIAL

    There are no restrictions on the republication of material appearing 
in the Code of Federal Regulations.

INQUIRIES

    For a legal interpretation or explanation of any regulation in this 
volume, contact the issuing agency. The issuing agency's name appears at 
the top of odd-numbered pages.
    For inquiries concerning CFR reference assistance, call 202-523-5227 
or write to the Director, Office of the Federal Register, National 
Archives and Records Administration, Washington, DC 20408 or e-mail 
[email protected].

SALES

    The Government Printing Office (GPO) processes all sales and 
distribution of the CFR. For payment by credit card, call 202-512-1800, 
M-F 8 a.m. to 4 p.m. e.s.t. or fax your order to 202-512-2250, 24 hours 
a day. For payment by check, write to the Superintendent of Documents, 
Attn: New Orders, P.O. Box 371954, Pittsburgh, PA 15250-7954. For GPO 
Customer Service call 202-512-1803.

ELECTRONIC SERVICES

    The full text of the Code of Federal Regulations, the LSA (List of 
CFR Sections Affected), The United States Government Manual, the Federal 
Register, Public Laws, Public Papers, Weekly Compilation of Presidential 
Documents and the Privacy Act Compilation are available in electronic 
format at www.access.gpo.gov/nara (''GPO Access''). For more 
information, contact Electronic Information Dissemination Services, U.S. 
Government Printing Office. Phone 202-512-1530, or 888-293-6498 (toll-
free). E-mail, [email protected].

[[Page vii]]

    The Office of the Federal Register also offers a free service on the 
National Archives and Records Administration's (NARA) World Wide Web 
site for public law numbers, Federal Register finding aids, and related 
information. Connect to NARA's web site at www.nara.gov/fedreg. The NARA 
site also contains links to GPO Access.

                              Raymond A. Mosley,
                                    Director,
                          Office of the Federal Register.

October 1, 2001.

[[Page ix]]

                               THIS TITLE

    Title 48--Federal Acquisition Regulations System is composed of 
seven volumes. The chapters in these volumes are arranged as follows: 
Chapter 1 (parts 1 to 51), chapter 1 (parts 52 to 99), chapter 2 (parts 
201 to 299), chapters 3 to 6, chapters 7 to 14, chapters 15 to 28 and 
chapter 29 to end. The contents of these volumes represent all current 
regulations codified under this title of the CFR as of October 1, 2001.

    The Federal acquisition regulations in chapter 1 are those 
government-wide acquisition regulations jointly issued by the General 
Services Administration, the Department of Defense, and the National 
Aeronautics and Space Administration. Chapters 2 through 99 are 
acquisition regulations issued by individual government agencies. Parts 
1 to 69 in each of chapters 2 through 99 are reserved for agency 
regulations implementing the Federal acquisition regulations in chapter 
1 and are numerically keyed to them. Parts 70 to 99 in chapters 2 
through 99 contain agency regulations supplementing the Federal 
acquisition regulations.

    The OMB control numbers for the Federal Acquisition Regulations 
System appear in section 1.106 of chapter 1. For the convenience of the 
user section 1.106 is reprinted in the Finding Aids section of the 
second volume containing chapter 1 (parts 52 to 99).

    The first volume, containing chapter 1 (parts 1 to 51), includes an 
index to the Federal acquisition regulations. 

[[Page x]]





[[Page 1]]



            TITLE 48--FEDERAL ACQUISITION REGULATIONS SYSTEM




                  (This book contains chapters 3 to 6)

  --------------------------------------------------------------------
                                                                    Part

chapter 3--Health and Human Services........................         301

chapter 4--Department of Agriculture........................         401

chapter 5--General Services Administration..................         501

chapter 6--Department of State..............................         601

[[Page 3]]



                  CHAPTER 3--HEALTH AND HUMAN SERVICES




  --------------------------------------------------------------------

                          SUBCHAPTER A--GENERAL
Part                                                                Page
301             HHS Acquisition Regulation System...........           5
302             Definitions of words and terms..............           8
303             Improper business practices and personal 
                    conflicts of interest...................          10
304             Administrative matters......................          11
           SUBCHAPTER B--COMPETITION AND ACQUISITION PLANNING
305             Publicizing contract actions................          14
306             Competition requirements....................          14
307             Acquisition planning........................          16
309             Contractor qualifications...................          25
          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
313             Simplified acquisition procedures...........          29
314             Sealed bidding..............................          29
315             Contracting by negotiation..................          30
316             Types of contracts..........................          47
317             Special contracting methods.................          49
                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
319             Small business programs.....................          50
323             Environment, conservation, occupational 
                    safety, and drug-free workplace.........          51
324             Protection of privacy and freedom of 
                    information.............................          52
325             Foreign acquisition.........................          54
             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
328             Bonds and insurance.........................          56
330             Cost accounting standards...................          56
332             Contract financing..........................          56
333             Protests, disputes, and appeals.............          59
             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING
334             Major system acquisition....................          64

[[Page 4]]

335             Research and development contracting........          64
                    SUBCHAPTER G--CONTRACT MANAGEMENT
342             Contract administration.....................          66
                     SUBCHAPTER H--CLAUSES AND FORMS
352             Solicitation provisions and contract clauses          71
353             Forms.......................................          83
                   SUBCHAPTER T--HHS SUPPLEMENTATIONS
370             Special programs affecting acquisition......          84

[[Page 5]]



                          SUBCHAPTER A_GENERAL

               PART 301_HHS ACQUISITION REGULATION SYSTEM

               Subpart 301.1_Purpose, Authority, Issuance

Sec.

Sec. 301.101  Purpose.

Sec. 301.103  Authority

Sec. 301.106  OMB approval under the Paperwork Reduction Act.

                      Subpart 301.2_Administration


Sec. 301.270  Executive Committee for Acquisition.

                  Subpart 301.4_Deviations from the FAR


Sec. 301.403  Individual deviations.

Sec. 301.404  Class deviations.

Sec. 301.470  Procedure.

      Subpart 301.6_Career Development, Contracting Authority, and 
                            Responsibilities


Sec. 301.602  Contracting officers.

Sec. 301.602-3  Ratification of unauthorized commitments.

Sec. 301.603  Selection, appointment, and termination of appointment.

Sec. 301.603-1  General.

Sec. 301.603-2  Selection.

Sec. 301.603-3  Appointment.

Sec. 301.603-4  Termination.

Sec. 301.603-70  Delegation of contracting officer responsibilities.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4220, Jan. 17, 2001, unless otherwise noted.

               Subpart 301.1_Purpose, Authority, Issuance



Sec. 301.101  Purpose.

    (a) The Department of Health and Human Services Acquisition 
Regulation (HHSAR) is issued to establish uniform acquisition policies 
and procedures for the Department of Health and Human Services (HHS) 
which conform to the Federal Acquisition Regulation (FAR) System.
    (b) The HHSAR implements and supplements the FAR. (Implementing 
material expands upon or indicates the manner of compliance with related 
FAR material. Supplementing material is new material which has no 
counterpart in the FAR.)
    (c) The HHSAR contains all formal departmental policies and 
procedures that govern the acquisition process or otherwise control 
contracting relationships between the Department's contracting offices 
and contractors.



Sec. 301.103  Authority.

    (b) The HHSAR is prescribed by the Assistant Secretary for 
Management and Budget under the authority of 5 U.S.C. 301 and section 
205(c) of the Federal Property and Administrative Services Act of 1949, 
as amended (40 U.S.C. 486(c)), as delegated by the Secretary.
    (c) The HHSAR is issued in the Code of Federal Regulations (CFR) as 
Chapter 3 of Title 48, Department of Health and Human Services 
Acquisition Regulation. It may be referenced as ``48 CFR Chapter 3.''



Sec. 301.106  OMB approval under the Paperwork Reduction Act.

    (a) The following OMB control numbers apply to the information 
collection and recordkeeping requirements contained in this chapter:

------------------------------------------------------------------------
                                                             OMB control
                       HHSAR segment                             No.
------------------------------------------------------------------------
315.4......................................................    0990-0139
324.70.....................................................    0990-0136
342.7101...................................................    0990-0131
352.224-70.................................................    0990-0137
352.224-70.................................................    0990-0136
352.233-70.................................................    0990-0133
352.270-1..................................................    0990-0129
352.270-2..................................................    0990-0129
352.270-3..................................................    0990-0129
352.270-5..................................................    0990-0130
352.270-8..................................................    0990-0128
352.270-9..................................................    0990-0128
370.1......................................................    0990-0129
370.2......................................................    0990-0129
------------------------------------------------------------------------

    (b) The OMB control number ``OMB No. 0990-0115'' is to be included 
in the upper right corner of the first page of all solicitations, 
purchase orders, and contracts issued by departmental contracting 
activities. The number represents approval of the HHS acquisition 
process and covers recordkeeping and reporting requirements which are 
unique to individual acquisitions (e.g.,

[[Page 6]]

requirements contained in specifications, statements of work, etc.).

                      Subpart 301.2_Administration



Sec. 301.270  Executive Committee for Acquisition.

    (a) The Deputy Assistant Secretary for Grants and Acquisition 
Management has established the Executive Committee for Acquisition (ECA) 
to assist and facilitate the planning and development of departmental 
acquisition policies and procedures and to assist in responding to other 
agencies and organizations concerning policies and procedures impacting 
the Federal acquisition process.
    (b) The ECA consists of members and alternates from the Office of 
Acquisition Management, Administration for Children and Families, Agency 
for Healthcare Research and Quality, Health Care Financing 
Administration, Program Support Center, Centers for Disease Control and 
Prevention, Food and Drug Administration, Health Resources and Services 
Administration, Indian Health Service, National Institutes of Health, 
and Substance Abuse and Mental Health Services Administration. The ECA 
is chaired by the Director, Office of Acquisition Management. All 
meetings will be held at the call of the Chair, and all activities will 
be carried out under the direction of the Chair.
    (c) The ECA, to facilitate the planning, development, and 
coordination of governmentwide and departmentwide acquisition policies 
and procedures, is to:
    (1) Advise and assist the Chair concerning major acquisition policy 
matters;
    (2) Review and appraise, at appropriate intervals, the overall 
effectiveness of existing policies and procedures; and
    (3) Review and appraise the impact of new major acquisition 
policies, procedures, regulations, and development on current 
acquisition policies and procedures.
    (d) The Chair will periodically issue a list of current members and 
alternates specifying the name, title, organization, address, and 
telephone number of each. The member organizations are responsible for 
apprising the Chair whenever a new member or alternate is to be 
appointed to the ECA, or an organizational change retitles the 
individual or organization.

                  Subpart 301.4_Deviations From the FAR



Sec. 301.403  Individual deviations.

    Requests for individual deviations to either the FAR or HHSAR shall 
be prepared in accordance with 301.470 and forwarded through 
administrative channels to the Director, Office of Acquisition 
Management for review and approval.



Sec. 301.404  Class deviations.

    Requests for class deviations to either the FAR or HHSAR shall be 
prepared in accordance with 301.470 and forwarded through administrative 
channels to the Deputy Assistant Secretary for Grants and Acquisition 
Management for review and approval.



Sec. 301.470  Procedure.

    (a) When a contracting office determines that a deviation is needed, 
it shall prepare a deviation request in memorandum form and forward it 
through administrative channels to the official designated in 301.403 or 
301.404. In an exigency situation, the contracting office may request a 
deviation verbally, through normal acquisition channels, but is required 
to confirm the request in writing as soon as possible.
    (b) A deviation request shall clearly and precisely set forth the:
    (1) Nature of the needed deviation;
    (2) Identification of the FAR or HHSAR citation from which the 
deviation is needed;
    (3) Circumstances under which the deviation would be used;
    (4) Intended effect of the deviation;
    (5) Period or applicability;
    (6) Reasons which will contribute to complete understanding and 
support of the requested deviation. A copy of pertinent background 
papers such as a contractor's request should accompany the deviation 
request.; and
    (7) Suggested wording for the deviation (if applicable).

[[Page 7]]

      Subpart 301.6_Career Development, Contracting Authority, and 
                            Responsibilities



Sec. 301.602  Contracting officers.



Sec. 301.602-3  Ratification of unauthorized commitments.

    (b) Policy. (1) The Government is not bound by agreements or 
contractual commitments made to prospective contractors by persons to 
whom contracting authority has not been delegated. However, execution of 
otherwise proper contracts made by individuals without contracting 
authority, or by contracting officers in excess of the limits of their 
delegated authority, may be later ratified. The ratification must be in 
the form of a written document clearly stating that ratification of a 
previously unauthorized act is intended and must be signed by the head 
of the contracting activity (HCA).
    (2) The HCA is the official authorized to ratify an unauthorized 
commitment (but see paragraph (b)(3) of this section).
    (3) Ratification authority for actions up to $25,000 may be 
redelegated by the HCA to the chief of the contracting office (CCO). No 
other redelegations are authorized.
    (c) Limitations. (5) The concurrence of legal counsel concerning the 
payment issue is optional.
    (e) Procedures. (1) The individual who made the unauthorized 
contractual commitment shall furnish the reviewing contracting officer 
all records and documents concerning the commitment and a complete 
written statement of facts, including, but not limited to: a statement 
as to why the contracting office was not used, a statement as to why the 
proposed contractor was selected, a list of other sources considered, a 
description of work to be performed or products to be furnished, the 
estimated or agreed contract price, a citation of the appropriation 
available, and a statement whether the contractor has commenced 
performance.
    (2) The contracting officer will review the submitted material, and 
prepare the ratification document if he/she determines that the 
commitment may be ratifiable. The contracting officer shall forward the 
ratification document and the submitted material to the HCA or CCO with 
any comments or information which should be considered in evaluation of 
the request for ratification. If legal review is desirable, the HCA or 
CCO will coordinate the request for ratification with the Office of 
General Counsel, Business and Administrative Law Division.
    (3) If ratification is authorized by the HCA or CCO, the file will 
be returned, along with the ratification document, to the contracting 
officer for issuance of a purchase order or contract, as appropriate.



Sec. 301.603  Selection, appointment, and termination of appointment.



Sec. 301.603-1  General.

    (a) The appointment and termination of appointment of contracting 
officers shall be made by the head of the contracting activity (HCA). 
This authority is not delegable.
    (b) The contracting officer appointment document for personnel in 
the GS-1101, 1102, and 1105 series, as well as personnel in any other 
series who will obligate the Government to the expenditure of funds in 
excess of the micro-purchase threshold, shall be the Standard Form 
(SF)--1402, Certificate of Appointment. The HCA may determine an 
alternative appointment document for appointments at or below that 
threshold. Changes to appointments shall be made by issuing a new 
appointment document. Each appointment document shall be prepared and 
maintained in accordance with FAR 1.603-1 and shall state the limits of 
the individual's authority.
    (c) An individual must be certified at the appropriate level under 
the HHS Acquisition Certification Program as a prerequisite to being 
appointed as a contracting officer with authority to obligate funds in 
excess of the micro-purchase threshold (see 301.603-3(a)). The HCA will 
determine and require appropriate training for individuals appointed as 
contracting officers at lower dollar levels. An individual shall be 
appointed as a contracting officer only in instances where a valid 
organizational need can be demonstrated. Factors to be considered in 
assessing the need for

[[Page 8]]

an appointment of a contracting officer include volume of actions, 
complexity of work, and structure of the organization.



Sec. 301.603-2  Selection.

    Nominations for appointment of contracting officers shall be 
submitted to the HCA through appropriate organizational channels for 
review. The nomination package, which is usually initiated by the 
prospective contracting officer's immediate supervisor, shall normally 
include the nominee's current personal qualifications statement or job 
history, including the information required by FAR 1.603-2, a copy of 
his/her most recent performance appraisal, and a copy of the certificate 
issued under the HHS Acquisition Certification Program indicating the 
nominee's current certification level, if applicable. The HCA will 
determine the documentation required, consistent with FAR 1.603-2, when 
the resulting appointment and authority will not exceed the micro-
purchase threshold.



Sec. 301.603-3  Appointment.

    (a) Contracting officer appointments shall be made at levels 
commensurate with nominees' certification levels as follows:
    (1) Level I--Purchasing Agent--Required for all personnel in the GS-
1102 and 1105 series having signature authority for simplified 
acquisitions, including orders from GSA sources over the micro-purchase 
threshold.
    (2) Level II--Acquisition Official--Required for all personnel in 
the GS-1102 series. Sufficient for delegation of contracting officer 
authority up to $500,000.
    (3) Level III--Senior Acquisition Official--Required for all 
personnel in the GS-1102 series for delegation of contracting officer 
authority above $500,000.
    (4) Level IV--Acquisition Manager--Required for delegation of pre-
award review and approval authority as specified in subpart 304.71.
    (b) If it is essential to appoint an individual who does not fully 
meet the certification requirements of this section for the contracting 
officer authority sought, an interim appointment may be granted by the 
HCA. Interim appointments may not exceed one (1) year in total, and 
shall not be granted unless the individual can meet the certification 
requirements within one year from the date of appointment. If the 
certification requirements are not met by that date, the appointment 
will automatically terminate and cannot be renewed.



Sec. 301.603-4  Termination.

    Termination of contracting officer appointments shall be 
accomplished in accordance with FAR 1.603-4.



Sec. 301.603-70  Delegation of contracting officer responsibilities.

    (a) Contracting officer responsibilities which do not involve the 
obligation (or deobligation) of funds or result in establishing or 
modifying contractual provisions may be delegated by the contracting 
officer by means of a written memorandum which clearly delineates the 
delegation and its limits.
    (b) Contracting officers may designate individuals as ordering 
officials to make purchases or place orders under blanket purchase 
agreements, indefinite delivery contracts, or other pre-established 
mechanisms. Ordering officials, including those under NIH's DELPRO, are 
not contracting officers.
    (c) Project officers are required to complete the training specified 
in 307.170, while ordering officials and others should receive 
sufficient instruction from the contracting officer to ensure the 
appropriate exercise of the responsibilities and knowledge of their 
limitations.

                 PART 302_DEFINITIONS OF WORDS AND TERMS

                        Subpart 302.1_Definitions

Sec.

Sec. 302.101  Definitions.

                    Subpart 302.2_Definitions Clause


Sec. 302.201  Contract clause.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4222, Jan. 17, 2001, unless otherwise noted.

[[Page 9]]

                        Subpart 302.1_Definitions



Sec. 302.101  Definitions.

    Chief of the contracting office (CCO) is a mid-level management 
official in charge of a contracting office who controls and oversees the 
daily contracting operation of an Operating Division (OPDIV) or major 
component of an OPDIV. The CCO is subordinate to the head of the 
contracting activity, and is located at a management level above other 
contracting personnel, usually as a branch chief or division director.
    Head of the agency or agency head, unless otherwise specified, means 
the head of the Operating Division (OPDIV) for ACF, AHRQ, HCFA, PSC, 
CDCP, FDA, HRSA, IHS, NIH, and SAMHSA, or the Assistant Secretary for 
Management and Budget (ASMB) for the Office of the Secretary (OS).
    Head of the contracting activity (HCA) is defined in terms of 
certain organizational positions within the Office of Grants and 
Acquisition Management (OGAM), Administration for Children and Families 
(ACF), Agency for Healthcare Research and Quality (AHRQ), Health Care 
Financing Administration (HCFA), Program Support Center (PSC), Centers 
for Disease Control and Prevention (CDCP), Food and Drug Administration 
(FDA), Health Resources and Services Administration (HRSA), Indian 
Health Service (IHS), National Institutes of Health (NIH), and Substance 
Abuse and Metal Health Services Administration (SAMHSA), as follows:

OGAM-OS--Director, Office of Acquisition Management
ACF--Director, Division of Acquisition Management
AHRQ--Director, Division of Contracts Management
HCFA--Director, Acquisition and Grants Group
PSC--Director, Division of Acquisition Management
CDCP--Director, Procurement and Grants Office
FDA--Director, Policy, Evaluation and Support Staff, Office of 
Facilities, Acquisition, and Central Services
HRSA--Director, Division of Grants and Procurement Management
IHS--Director, Division of Acquisitions and Grants Management
NIH--Director, Office of Acquisition Management and Policy
SAMHSA--Director, Division of Contracts Management

    In addition, the Deputy Assistant Secretary for Grants and 
Acquisition Management (DASGAM) is designated as an HCA. Each HCA is 
responsible for conducting an effective and efficient acquisition 
program. Adequate controls shall be established to assure compliance 
with applicable laws, regulations, procedures, and the dictates of good 
management practices. Periodic reviews shall be conducted and evaluated 
by qualified personnel, preferably assigned to positions other than in 
the contracting office being reviewed, to determine the extent of 
adherence to prescribed policies and regulations, and to detect a need 
for guidance and/or training. The HCA shall be certified, or be 
certifiable, at Level IV of the HHS Acquisition Certification Program. 
Individuals appointed as HCA's who do not meet the Level IV requirements 
shall have one year from the date of appointment to obtain Level IV 
certification. The heads of contracting activities may redelegate their 
HCA authorities to the extent that redelegation is not prohibited by the 
terms of their respective delegations of authority, by law, by the 
Federal Acquisition Regulation, by the HHS Acquisition Regulation, or by 
other regulations. However, HCA and other contracting approvals and 
authorities shall not be redelegated below the levels specified in the 
HHS Acquisition Regulation or, in the absence of coverage in the HHS 
Acquisition Regulation, the Federal Acquisition Regulation. To ensure 
proper control of redelegated acquisition authorities, HCA's shall 
maintain a file containing successive delegations of HCA authority 
through and including the contracting officer level. Personnel delegated 
responsibility for acquisition functions must possess a level of 
experience, training, and ability commensurate with the complexity and 
magnitude of the acquisition actions involved.

[[Page 10]]

                    Subpart 302.2_Definitions Clause



Sec. 302.201  Contract clause.

    The FAR clause, Definitions, at 52.202-1 shall be used as prescribed 
in FAR 2.201, except as follows:
    (a) Paragraph (a) at 352.202-1 shall be used in place of paragraph 
(a) of the FAR clause.
    (b) Paragraph (h), or its alternate, at 352.202-1 shall be added to 
the end of the FAR clause. Use paragraph (h) when a fixed-priced 
contract is anticipated; use the alternate to paragraph (h) when a cost-
reimbursement contract is anticipated. This is an authorized deviation.

 PART 303_IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST

                        Subpart 303.1_Safeguards

Sec.

Sec. 303.101  Standards of conduct.

Sec. 303.101-3  Agency regulations.

        Subpart 303.2_Contract Gratuities to Government Personnel


Sec. 303.203  Reporting suspected violations of the Gratuities clause.

         Subpart 303.3_Reports of Suspected Antitrust Violations


Sec. 303.303  Reporting suspected antitrust violations.

                      Subpart 303.4_Contingent Fees


Sec. 303.405  Misrepresentations or violations of the Covenant Against 
          Contingent Fees.

Subpart 303.6_Contracts With Government Employees or Organizations Owned 
                          or Controlled by Them


Sec. 303.602  Exceptions.

             Subpart 303.7_Voiding and Rescinding Contracts


Sec. 303.704  Policy.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4223, Jan. 17, 2001, unless otherwise noted.

                        Subpart 303.1_Safeguards



Sec. 303.101  Standards of conduct.



Sec. 303.101-3  Agency regulations.

    The Department of Health and Human Services' Standards of Conduct 
are prescribed in 45 CFR part 73.

       Subpart 303.2_Contractor Gratuities to Government Personnel



Sec. 303.203  Reporting suspected violations of the Gratuities clause.

    Departmental personnel shall report suspected violations of the 
Gratuities clause in accordance with subpart M, Reporting Violations, of 
45 CFR part 73. Refer to subpart B, Gifts from Outside Sources, (5 CFR 
2635.201) for an explanation regarding what is prohibited and what is 
permitted.

         Subpart 303.3_Reports of Suspected Antitrust Violations



Sec. 303.303  Reporting suspected antitrust violations.

    A copy of each report of suspected antitrust violations submitted to 
the Attorney General by the HCA shall also be submitted to the Director, 
Office of Acquisition Management.

                      Subpart 303.4_Contingent Fees



Sec. 303.405  Misrepresentations or violations of the Covenant Against 
          Contingent Fees.

    (c) Reports shall be made promptly to the contracting officer.
    (d)(4) Suspected fraudulent or criminal matters to be reported to 
the Department of Justice shall be prepared in letter format and 
forwarded through acquisition channels to the head of the contracting 
activity for signature. The letter must contain all pertinent facts and 
background information considered by the contracting officer and chief 
of the contracting office that led to the decision that fraudulent or 
criminal matters may be present. A copy of the signed letter shall be 
sent to the Director, Office of Acquisition Management.

[[Page 11]]

Subpart 303.6_Contracts With Government Employees or Organizations Owned 
                          or Controlled by Them



Sec. 303.602  Exceptions.

    Approval of an exception to the policy stated in FAR 3.601 shall be 
made by the HCA (not delegable).

             Subpart 303.7_Voiding and Rescinding Contracts



Sec. 303.704  Policy.

    For purposes of implementing FAR subpart 3.7, the authorities 
granted to the ``agency head or designee'' shall be exercised by the HCA 
(not delegable).

                     PART 304_ADMINISTRATIVE MATTERS

                    Subpart 304.6_Contract Reporting

Sec.

Sec. 304.602  Federal Procurement Data System (FPDS).

                 Subpart 304.8_Government Contract Files


Sec. 304.804-70  Contract closeout audits.

  Subpart 304.70_Acquisition Instrument Identification Numbering System


Sec. 304.7000  Scope of subpart.

Sec. 304.7001  Numbering acquisitions.

     Subpart 304.71_Review and Approval of Proposed Contract Awards


Sec. 304.7100  Policy.

Sec. 304.7101  Procedures.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4224, Jan. 17, 2001, unless otherwise noted.

                   Subpart 304.6_Contracting Reporting



Sec. 304.602  Federal Procurement Data System (FPDS).

    The Departmental Contracts Information System (DCIS) represents the 
Department's implementation of the FPDS. All departmental contracting 
activities are required to participate in the DCIS and follow the 
procedures stated in the Enhanced Departmental Contracts Information 
System Manual and amendments to it. The HCA (not delegable) shall ensure 
that all required contract information is collected, submitted, and 
received into the DCIS on or before the 15th of each month for all 
appropriate contract and contract modifications award of the prior 
month.

                 Subpart 304.8_Government Contract Files



Sec. 304.804-70  Contract closeout audits.

    (a) Contracting officers shall rely, to the maximum extent possible, 
on non-Federal single audits to close physically completed cost-
reimbursement contracts with colleges and universities, hospitals, non-
profit firms, and State and local governments. In addition, where 
appropriate, a sample of these contractors may be selected for audit, in 
accordance with the decision-making process set forth in the following 
paragraph (b).
    (b) Contracting officers shall request contract closeout audits on 
physically completed, cost-reimbursement, for-profit contracts in 
accordance with the following:
    (1) Decisions on: The need for and allocation of contract audit 
resources and services; the selection of contracts or contractors to be 
audited; the identification of the audit agency to perform the audit; 
and the type or scope of closeout audit to be conducted, shall be made 
by the Office of Inspector General (OIG) and Office of Grants and 
Acquisition Management, in consultation with the Department's Contract 
Audit Users Work Group. These decisions shall be based upon the needs of 
the customer, risk analysis, return on investment, and the availability 
of audit resources. When an audit is warranted prior to closing a 
contract, the contracting officer shall submit the audit request to the 
OIG's Office of Audit via the appropriate OPDIV representative on the 
Contract Audit Users Work Group.
    (2) Except where a contracting officer suspects misrepresentation or 
fraud, contract closeout field audits shall not be requested if the cost 
of performance is likely to exceed the potential cost recovery. 
Contracts that are not selected for a field audit may be closed

[[Page 12]]

on the basis of a desk review, subject to any later on-site audit 
findings. The release executed by the contractor shall contain the 
following statement:

    The Contractor agrees, pursuant to the clause in this contract 
entitled ``Allowable Cost'' or ``Allowable Cost and Fixed Fee'' (as 
appropriate), that the amount of any sustained audit exceptions 
resulting from any audit made after final payment shall be refunded to 
the Government.''

  Subpart 304.70_Acquisition Instrument Identification Numbering System



Sec. 304.7000  Scope of subpart.

    This subpart prescribes policy and procedures for assigning 
identifying numbers to contracts and related instruments, including 
solicitation documents, purchase orders, and delivery orders. The HCA 
(not delegable) is responsible for establishing the numbering system 
within the OPDIV.



Sec. 304.7001  Numbering acquisitions.

    (a) Acquisitions which require numbering. The following acquisitions 
shall be numbered in accordance with the system prescribed in paragraphs 
(b) and (c) of this section:
    (1) Contracts, including letter contracts and task orders under 
basic ordering agreements, which involve the payment of $2,500 or more 
for the acquisition of personal property or nonpersonal services. (The 
number assigned to a letter contract shall be assigned to the 
superseding definitized contract).
    (2) Contracts which involve the payment of $2,000 or more for 
construction (including renovation or alteration).
    (3) Contracts which involve more than one payment regardless of 
amount.
    (4) Requests for proposals and invitations for bids.
    (5) Requests for quotations.
    (6) Basic ordering agreements.
    (b) Numbering system for contracts. All contracts which require 
numbering (paragraphs (a)(1) through (3) of this section) shall be 
assigned a number consisting of the following:
    (1) The three digit identification code assigned to the contracting 
office by the Office of Grants and Acquisition Management (OGAM).
    (2) A two digit fiscal year designation; and
    (3) A four digit serial number. For example, the initial contract 
executed by the Office of Acquisition Management, OS, for fiscal year 
1996 would be numbered 100-96-0001. While it is required that a 
different series of four digit serial numbers be used for each fiscal 
year, serial numbers assigned need not be sequential.
    (c) Numbering system for other acquisitions. The HCA is responsible 
for developing a numbering system for the acquisitions other than 
contracts listed in paragraphs, (a)(4) through (a)(6) of this section, 
and any other types of acquisitions that may be used.
    (d) Assignment of identification codes. Each contracting office of 
the Department shall be assigned a three digit identification code by 
the OGAM. Requests for the assignment of codes for newly established 
contracting offices shall be submitted by the headquarters acquisition 
staff office of the contracting activity to the OGAM. A listing of the 
contracting office identification codes currently in use is contained in 
the Enhanced Departmental Contracts Information System Manual.

     Subpart 304.71_Review and Approval of Proposed Contract Awards



Sec. 304.7100  Policy.

    This subpart requires each HCA (not delegable) to establish review 
and approval procedures for proposed contracts actions to ensure that:
    (a) Contract awards are in conformance with law, established 
policies and procedures, and sound business practices;
    (b) Contractual documents properly reflect the mutual understanding 
of the parties; and
    (c) The contracting officer is informed of deficiencies and items of 
questionable acceptability, and corrective action is taken.

[[Page 13]]



Sec. 304.7101  Procedures.

    (a) All contractual documents, regardless of dollar value, are to be 
reviewed by the contracting officer prior to award.
    (b) The HCA is responsible for establishing review and approval 
procedures and designating acquisition officials to serve as reviewers. 
Each HCA is responsible for determining the criterion (criteria) to be 
used in determining which contracts are to be reviewed, and that a 
sampling of proposed contracts not included in the ``to be reviewed'' 
group are reviewed and approved.
    (c) Officials assigned responsibility for review and approval of 
contract actions must possess qualifications in the field of acquisition 
commensurate with the level of review performed, and, at a minimum, 
possess those acquisition skills expected of a contracting officer. 
However, if any official is to serve as the contracting officer and sign 
the contractual document, the review and approval function shall be 
performed by an appropriate official at least one level above.

[[Page 14]]



            SUBCHAPTER B_COMPETITION AND ACQUISITION PLANNING

                  PART 305_PUBLICIZING CONTRACT ACTIONS

           Subpart 305.2_Synopsis of Proposed Contract Actions

Sec.

Sec. 305.202  Exceptions.

                Subpart 305.3_Synopsis of Contract Awards


Sec. 305.303  Announcement of contract awards.

                    Subpart 305.5_Paid Advertisements


Sec. 305.502  Authority.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4225, Jan. 17, 2001, unless otherwise noted.

           Subpart 305.2_Synopsis of Proposed Contract Actions



Sec. 305.202  Exceptions.

    (b) When a contracting office believes that it has a situation where 
advance notice is not appropriate or reasonable, it shall prepare a 
memorandum citing all pertinent facts and details and send it, through 
normal acquisition channels, to the Deputy Assistant Secretary for 
Grants and Acquisition Management (DASGAM) requesting relief from 
synopsizing. The DASGAM shall review the request and decide whether an 
exception to synopsizing is appropriate or reasonable. If it is, the 
DASGAM shall take the necessary coordinating actions required by FAR 
5.202 (b). Whatever the decision is on the request, the DASGAM shall 
promptly notify the contracting office when a determination has been 
made.

                Subpart 305.3_Synopses of Contract Awards



Sec. 305.303  Announcement of contract awards.

    (a) Public announcement. Any contract, contract modification, or 
delivery order in the amount of $3 million or more shall be reported by 
the contracting officer to the Office of the Deputy Assistant Secretary 
for Legislation (Congressional Liaison), Room 406G, Hubert H. Humphrey 
Building. Notification shall be accomplished by providing a copy of the 
contract or award document face page to the referenced office prior to 
the day of award, or in sufficient time to allow for an announcement to 
be made by 5 p.m. Washington, DC time on the day of award.

                    Subpart 305.5_Paid Advertisements



Sec. 305.502  Authority.

    The contracting officer is authorized to publish advertisements, 
notices, and notices that proposals are being sought in newspapers and 
periodicals in accordance with the requirements and conditions 
referenced in FAR subpart 5.5.

                    PART 306_COMPETITION REQUIREMENTS

   Subpart 306.2_Full and Open Competition After Exclusion of Sources

Sec.

Sec. 306.202  Establishing or maintaining alternative sources.

           Subpart 306.3_Other Than Full and Open Competition


Sec. 306.302  Circumstances permitting other than full and open 
          competition.

Sec. 306.302-1  Only one responsible source and no other supplies or 
          services will satisfy agency requirements.

Sec. 306.302-7  Public interest.

Sec. 306.303  Justification.

Sec. 306.303-1  Requirements

Sec. 306.303-2  Content.

Sec. 306.304  Approval of the justification.

                   Subpart 306.5_Competition Advocates


Sec. 306.501  Requirement.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4225, Jan. 17, 2001, unless otherwise noted.

[[Page 15]]

   Subpart 306.2_Full and Open Competition After Exclusion of Sources



Sec. 306.202  Establishing or maintaining alternative sources.

    (a) The reference to the agency head in FAR 6.202 (a) shall mean the 
appropriate competition advocate cited in 306.501.
    (b)(1) The required determination and findings (D&F) shall be 
prepared by the contracting officer based on the data provided by 
program personnel, and shall be signed by the appropriate competition 
advocate. The D&F signatory is not delegable.

           Subpart 306.3_Other Than Full and Open Competition



Sec. 306.302  Circumstances permitting other than full and open 
          competition.



Sec. 306.302-1  Only one responsible source and no other supplies or 
          services will satisfy agency requirements.

    (a) (2) (ii) Follow-on contracts for the continuation of major 
research and development studies on long-term social and health 
programs, major research studies, or clinical trials may be deemed to be 
available only from the original source when it is likely that award to 
any other source would result in unacceptable delays in fulfilling the 
Department's or OPDIV's requirements.
    (b) Application. (4) When the head of the program office has 
determined that a specific item of technical equipment or parts must be 
obtained to meet the activity's program responsibility to test and 
evaluate certain kinds and types of products, and only one source is 
available. (This criterion is limited to testing and evaluation purposes 
only and may not be used for initial outfitting or repetitive 
acquisitions. Project officers should support the use of this criterion 
with citations from their agency's legislation and the technical 
rationale for the item of equipment required.)



Sec. 306.302-7  Public interest.

    (a) Authority. (2) Agency head, in this instance, means the 
Secretary.
    (c) Limitations. An ``approval package'' must be prepared by the 
contracting officer and staffed through departmental acquisition 
channels to the Secretary. The package shall include a determination and 
findings for the Secretary to sign that contains all pertinent 
information to support justification for exercising the exemption to 
competition, and a letter for the Secretary to sign notifying Congress 
of the determination to award a contract under the authority of 41 
U.S.C. 253(c)(7).



Sec. 306.303  Justifications.



Sec. 306.303-1  Requirements.

    (b) Preliminary arrangements or agreements with the proposed 
contractor shall have no effect on the rationale used to support an 
acquisition for other than full and open competition.
    (f) When a program office desires to obtain certain goods or 
services by contract without full and open competition, it shall, at the 
time of forwarding the requisition or request for contract, furnish the 
contracting office a justification explaining why full and open 
competition is not feasible. All justifications shall be initially 
reviewed by the contracting officer.
    (1) Justifications in excess of the simplified acquisition threshold 
shall be in the form of a separate, self-contained document, prepared in 
accordance with FAR 6.303 and 306.303, and called a ``JOFOC'' 
(Justification for Other Than Full and Open Competition). Justifications 
at or below the simplified acquisition threshold may be in the form of a 
paragraph or paragraphs contained in the requisition or request for 
contract.
    (2) Justifications, whether over or under the simplified acquisition 
threshold, shall fully describe what is to be acquired, offer reasons 
which go beyond inconvenience, and explain why it is not feasible to 
obtain competition. The justifications shall be supported by verifiable 
facts rather than mere opinions. Documentation in the justification 
should be sufficient to permit an individual with technical competence 
in the area to follow the rationale.

[[Page 16]]



Sec. 306.303-2  Content.

    (a)(1) The program office and name, address, and telephone number of 
the project officer shall also be included.
    (2) This item shall include project identification such as the 
authorizing program legislation, to include citations or other internal 
program identification data such as title, contract number, etc.
    (3) The description may be in the form of a statement of work, 
purchase description, or specification. A statement is to be included to 
explain whether the acquisition is an entity in itself, whether it is 
one in a series, or part of a related group of acquisitions.
    (c) Each JOFOC shall conclude with at least signature lines for the 
project officer, project officer's immediate supervisor, contracting 
officer, and approving official.



Sec. 306.304  Approval of the justification.

    (a)(2) The competition advocates are listed in 306.501. This 
authority is not delegable.
    (3) The competition advocate shall exercise this approval authority, 
except where the individual designated as the competition advocate does 
not meet the requirements of FAR 6.304 (a)(3)(ii). This authority is not 
delegable.
    (4) The senior procurement executive of the Department is the 
Assistant Secretary for Management and Budget.
    (c) A class justification shall be processed the same as an 
individual justification.

                   Subpart 306.5_Competition Advocates



Sec. 306.501  Requirement.

    The Department's competition advocate is the Deputy Assistant 
Secretary for Grants and Acquisition Management. The competition 
advocates for the Department's primary contracting officers are as 
follows:

ACF--Director, Office of Management Services
HCFA--Director, Office of Internal Customer Support
OS--Deputy Assistant Secretary for Grants and Acquisition Management
PSC--Director, Administrative Operations Service
AHRQ--Executive Officer
CDCP--Director, Office of Program Support
FDA--Director, Office of Facilities, Acquisition, and Central Services
HRSA--Associate Administrator for Operations and Management
IHS--Director, Office of Management and Support
NIH--(R&D)--Director, Office of Extramural Research (Other than R&D)--
Director, Office of Intramural Research
SAMHSA--Associate Administrator for Management

                      PART 307_ACQUISITION PLANNING

                     Subpart 307.1_Acquisition Plans

Sec.

Sec. 307.104  General procedures.

Sec. 307.105  Contents of written acquisition plans.

Sec. 307.170  Program training requirements.

Sec. 307.170-1  Policy exceptions.

Sec. 307.170-2  Training course prerequisites.

         Subpart 307.3_Contractor Versus Government Performance


Sec. 307.302  General.

Sec. 307.303  Determining availability of private commercial sources.

Sec. 307.304  Procedures.

Sec. 307.307  Appeals.

     Subpart 307.70_Considerations in Selecting an Award Instrument


Sec. 307.7000  Scope of subpart.

Sec. 307.7001  Distinction between acquisition and assistance.

Sec. 307.7002  Procedures.

                  Subpart 307.71_Requests for Contract


Sec. 307.7100  Scope of subpart.

Sec. 307.7101  General.

Sec. 307.7102  Procedures.

Sec. 307.7103  Responsibilities.

Sec. 307.7104  Transmittal.

Sec. 307.7105  Format and content.

Sec. 307.7106  Statement of work.

Sec. 307.7107  Review.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source:  66 FR 4226, Jan. 17, 2001, unless otherwise noted.

                   Subpart 307.1_Acquisition Planning



Sec. 307.104  General procedures.

    (d) Each contracting activity shall prepare an Annual Acquisition 
Plan

[[Page 17]]

(AAP). The AAP is a macro plan, containing a list of anticipated 
contract actions over the simplified acquisition threshold and their 
associated funding, as well as the aggregate planned dollars for 
simplified acquisitions by quarter, developed for each fiscal year. The 
AAP shall conform to reasonable budget expectations and shall be 
reviewed at least quarterly and modified as appropriate. The chief of 
the contracting office (CCO) shall obtain this information from the 
program planning/budget office of the contracting activity and use the 
AAP to provide necessary reports and monitor the workload of the 
contracting office. For contract actions, the plan shall contain, at a 
minimum:
    (1) A brief description (descriptive title, perhaps one or two 
sentences if necessary);
    (2) Estimated award amount;
    (3) Requested award date;
    (4) Name and phone number of contact person (usually the project 
officer);
    (5) Other information required for OPDIV needs.
    (e) Once the AAP is obtained, the contracting officer/contract 
specialist shall initiate discussions with the assigned project officer 
for each planned negotiated acquisition over $100,000 except for:
    (1) Acquisitions made under interagency agreements, and
    (2) Contract modifications which exercise options, make changes 
authorized by the Changes clause, or add funds to an incrementally 
funded contract. (The HCA may prescribe procedures for contract actions 
not covered by this subpart.)
    (f) The purpose of the discussions between the contracting and 
project officers is to develop an individual acquisition planning 
schedule and to address the things that will need to be covered in the 
request for contract (RFC), including clearances, acquisition strategy, 
sources, etc. The project officer must either have a statement of work 
(SOW) ready at this time or must discuss in more detail the nature of 
the services/supplies that will be required.
    (g) Standard lead-times for processing various types of acquisitions 
and deadlines for submission of acceptable RFCs (that is, RFCs which 
include all required elements such as clearances, funding documents, and 
an acceptable SOW) for award in a given fiscal year shall be established 
by the HCA or designee not lower than the CCO.
    (h) The outcome of the discussions referenced in paragraph (f) of 
this section between the project officer and the contracting officer/
contracting specialist will be an agreement concerning the dates of 
significant transaction-specific acquisition milestones, including the 
date of submission of the RFC to the contracting officer. This milestone 
schedule document will be prepared with those dates and will be signed 
by the project officer and the contracting officer. The milestones 
cannot be revised except by mutual agreement of these same individuals. 
If the planning schedule indicates the need to obtain approval of a 
Justification for Other than Full and Open Competition, the CCO must 
sign the milestone agreement. This document shall be retained in the 
contract file. All other considerations that will affect the acquisition 
(technical, business, management) shall be addressed in the RFC (see 
307.71).



Sec. 307.105  Contents of written acquisition plans.

    The written acquisition plan required by FAR 7.105 must be contained 
in the request for contract, as specified in subpart 307.71, and is the 
final product of the planning process.



Sec. 307.170  Program training requirements.

    (i) All program personnel selected to serve as project officers for 
HHS contracts shall have successfully completed either the Department's 
appropriate ``Basic Project Officer'' course, or an equivalent course 
(see paragraph (c) of this section).
    (b) At least fifty percent of the HHS program personnel performing 
the function of technical proposal evaluator on a technical evaluation 
team or panel for any competitively solicited HHS contract shall have 
successfully completed the appropriate ``Basic Project Officer'' course, 
or an equivalent course (see paragraph (c) of this section). This 
requirement applies to

[[Page 18]]

the initial technical proposal evaluation and any subsequent technical 
evaluations that may be required.
    (c) Determination of course equivalency shall be made by the HCA 
(not delegable) of the cognizant contracting activity. The contracting 
officer is responsible for ensuring that the project officer and 
technical proposal evaluators have successfully completed the required 
training discussed in 307.170-2.



Sec. 307.170-1  Policy exceptions.

    In the event there is an urgent requirement for a specific 
individual to serve as a project officer and that individual has not 
successfully completed the prerequisite training course, the HCA (not 
delegable) may waive the training requirement and authorize the 
individual to perform the project duties, provided that:
    (a) The individual first meets with the cognizant contracting 
officer to review the DHHS Project Officers' Contracting Handbook,'' and 
to discuss the important aspects of the contracting--program office 
relationship as appropriate to the circumstances; and
    (b) The individual attends the next scheduled and appropriate 
``Basic Project Officer'' course.



Sec. 307.170-2  Training course prerequisites.

    (a) Project officers. (1) Newly appointed project officers, and 
project officers with less than three years experience and no previous 
related training, are required to take the appropriate ``Basic Project 
Officer'' course. (The grade level for project officers attending the 
course should be GS-7 and above.) All project officers are encouraged to 
take the appropriate ``Writing Statements of Work'' course.
    (2) Project officers with more than three years experience, and 
project officers with less than three years experience who have 
successfully completed the appropriate basic course, are qualified (and 
encouraged) to take the ``Advanced Project Officer'' course.
    (3) Additional information on prerequisites for attendance of these 
courses may be found in the ``DHHS Acquisition Training and 
Certification Program Handbook.''
    (b) Technical proposal evaluators. Technical proposal evaluators, 
regardless of experience, are required to take the appropriate ``Basic 
Project Officer'' course or its equivalent. Upon successful completion 
of the basic course, it is recommended that they take the appropriate 
``Advanced Project Officer'' course. Peer and objective reviewers are 
excluded from these requirements.

         Subpart 307.3_Contractor Versus Government Performance



Sec. 307.302  General.

    (a) General Administration Manual (GAM) Chapter 18-10, Commercial-
Industrial Activities of the Department of Health and Human Services 
Providing Products or Services for Government Use, assigns 
responsibilities for making method-of-performance decisions (contract 
vs. in-house performance) to various management levels within the 
Department depending on the dollar amount of capital investment or 
annual operating costs. It also requires that each operating division 
(OPDIV) and staff division (STAFFDIV) designate a ``Commercial-
Industrial Control Officer'' (CICO) to be responsible for ensuring 
compliance with the requirements of the Chapter.



Sec. 307.303  Determining availability of private commercial sources.

    In accordance with the provisions of GAM Chapter 18-10, OPDIVs and 
STAFFDIVs must prepare and maintain a complete inventory of all 
individual commercial or industrial activities. They must also conduct 
periodic reviews of each activity and contract in the inventory to 
determine if the existing performance, in-house or by contract, 
continues to be in accordance with the policy guidelines of GAM Chapter 
18-10.



Sec. 307.304  Procedures.

    Contracting officers shall ensure that no acquisition action 
involving a commercial-industrial activity is initiated unless it is in 
compliance with the requirements of GAM Chapter 18-10. The contracting 
officer must check each request for contract expected to result in a 
contract in excess of $100,000 to ensure that it contains a statement as 
to

[[Page 19]]

whether the proposed contract is or is not subject to review under GAM 
Chapter 18-10 requirements. If the contracting officer has any questions 
regarding the determination of applicability or nonapplicability, or if 
the required statement is missing, the program office submitting the 
request for contract should be contacted and the situation rectified. If 
the issue cannot be resolved with the program office, the contracting 
office shall refer the matter to the CICO for a final determination. The 
HCA is responsible for ensuring that contracting activities are in full 
compliance with FAR Subpart 7.3.



Sec. 307.307  Appeals.

    The review and appeals procedure discussed in FAR 7.307 are 
addressed in GAM Chapter 18-10.

     Subpart 307.70_Considerations in Selecting an Award Instrument



Sec. 307.7000  Scope of subpart.

    This subpart provides guidance on the appropriate selection of award 
instruments consistent with 31 U.S.C. 6301-6308. This subpart explains 
the use of the contract as the award instrument for acquisition 
relationships, and the grant or cooperative agreement as the instrument 
for assistance relationships. This subpart provides guidance for 
determining whether to use the acquisition or assistance process to 
fulfill program needs.



Sec. 307.7001  Distinction between acquisition and assistance.

    (a) 31 U.S.C. 6301-6308 requires the use of contracts to acquire 
property or services for the direct benefit or use of the Government and 
grants or cooperative agreements to transfer money, property, services, 
or anything of value to recipients to accomplish a public purpose of 
support or stimulation authorized by Federal statute.
    (b) A contract is to be used as the legal instrument to reflect a 
relationship between the Federal Government and a recipient whenever:
    (1) The principal purpose of the instrument is the acquisition, by 
purchase, lease, or barter, of property or services for the direct 
benefit or use of the Federal Government; or
    (2) The Department determines in a specific instance that the use of 
a type of contract is appropriate. That is, it is determined in a 
certain situation that specific needs can be satisfied best by using the 
acquisition process. However, this authority does not permit 
circumventing the criteria for use of acquisition or assistance 
instruments. Use of this authority is restricted to extraordinary 
circumstances and only with the prior approval of the Deputy Assistant 
Secretary for Grants and Acquisition Management (DASGAM).
    (c) A grant or cooperative agreement is to be used as the legal 
instrument to reflect a relationship between the Federal Government and 
a recipient whenever the principal purpose of the relationship is the 
transfer of money, property, services, or anything of value to the 
recipient to accomplish a public purpose of support or stimulation 
authorized by Federal statute.
    (1) A grant is the legal instrument to be used when no substantial 
involvement is anticipated between the Department and the recipient 
during performance of the contemplated activity.
    (2) A cooperative agreement is the legal instrument to be used when 
substantial involvement is anticipated between the Department and the 
recipient during performance of the contemplated activity.
    (d) As a general rule, contracts are to be used for the following 
purposes:
    (1) Evaluation (including research of an evaluative nature) of the 
performance of Government programs or projects or grantee activity 
initiated by the funding agency for its direct benefit or use.
    (2) Technical assistance rendered to the Government, or on behalf of 
the Government, to any third party, including those receiving grants or 
cooperative agreements.
    (3) Surveys, studies, and research which provide specific 
information desired by the Government for its direct activities, or for 
dissemination to the public.
    (4) Consulting services or professional services of all kinds if 
provided to the Government or, on behalf of the Government, to any third 
party.

[[Page 20]]

    (5) Training projects where the Government selects the individuals 
or specific groups whose members are to be trained or specifies the 
content of the curriculum (not applicable to fellowship awards.)
    (6) Planning for Government use.
    (7) Production of publications or audiovisual materials required 
primarily for the conduct of the direct operations of the Government.
    (8) Design or development of items for Government use or pursuant to 
agency definition or specifications.
    (9) Conferences conducted on behalf of the Government.
    (10) Generation of management information or other data for 
Government use.



Sec. 307.7002  Procedures.

    (a) OPDIV program officials should use existing budget and program 
planning procedures to propose new activities and major changes in 
ongoing programs. It is the responsibility of these program officials to 
meet with the HCA and the principal grants management official, or their 
designees, to distinguish the relationships and determine whether award 
is to be made through the acquisition process or assistance process. 
This determination should be made prior to the time when the annual 
acquisition plan is reviewed and approved so that the plan will reflect 
all known proposed contract actions. The cognizant contracting officer 
will confirm the appropriateness of the use of the contract instrument 
when reviewing the request for contract.
    (b) Shifts from one award instrument to another must be fully 
documented in the appropriate files to show a fundamental change in 
program purpose that unequivocally justifies the rationale for the 
shift.
    (c) OPDIVs must ensure that the choice of instrument is determined 
in accordance with 31 U.S.C. 6301-6308 and applicable departmental 
policies. If, however, there are major individual transactions or 
programs which contain elements of both acquisition and assistance in 
such a way that they cannot be characterized as having a principal 
purpose of one or the other, guidance should be obtained from the 
DASGAM, through normal channels, before proceeding with a determination.
    (d) Any public notice, program announcement, solicitation, or 
request for applications or proposals must indicate whether the intended 
relationship will be one of acquisition or assistance and specify the 
award instrument to be used.

                  Subpart 307.71_Requests for Contract



Sec. 307.7100  Scope of subpart.

    This subpart prescribes the format and contents of the request for 
contract (RFC) and provides procedures for its preparation and 
submission.



Sec. 307.7101  General.

    The program office's preparation of the RFC and submission to the 
contracting office completes the presolicitation phase of the 
acquisition planning process and commences the solicitation phase. The 
RFC is the formal document which initiates the preparation of the 
solicitation by the contracting office and sets the acquisition process 
in motion. It is the result of the planning by the project officer and 
contracting officer and contains much of the pertinent information 
necessary for the development of a sound, comprehensive solicitation.



Sec. 307.7102  Procedures.

    The program office should submit the RFC to the contracting office 
no later than the date agreed to by the contracting officer and the 
project officer in the milestone schedule (see 307.104(h)), unless a 
revised due date has been established by mutual agreement.



Sec. 307.7103  Responsibilities.

    (a) It is the responsibility of the project officer to prepare the 
RFC so that it complies with the requirements of this subpart and any 
OPDIV guidance issued in accordance with this subpart.
    (b) Prior to the submission of the RFC to the contracting office, 
the head of the program office sponsoring the project shall review the 
RFC to ensure

[[Page 21]]

that all required information is provided in the prescribed format, and 
a technical review of the statement of work has been made. The level and 
extent of the technical review is to be commensurate with the estimated 
cost, importance, and complexity of the proposed acquisition, and must 
be thorough enough to ensure that vague and ambiguous language is 
eliminated, the statement of work is structured by phases or tasks, if 
appropriate, and methods are available for assessing the contractor's 
technical, cost, and delivery performance.



Sec. 307.7104  Transmittal.

    The RFC must be conveyed to the contracting office by use of a 
covering memorandum or other form of transmittal. The transmittal 
document must be signed by the head of the sponsoring program office and 
include both a statement attesting to the conclusiveness of the review 
described in 307.7103(b) and a list identifying all attachments to the 
RFC.



Sec. 307.7105  Format and content.

    The Department does not prescribe a standard format for the RFC. A 
format similar to what is in this section is recommended. However, any 
document or group of documents will be acceptable as an RFC as long as 
all of the required information (paragraph (a) of this section), and as 
much of the optional information (paragraph (b) of this section) as is 
relevant, is included.
    (a) The RFC must include:
    (1) Purpose of the contract. A brief, general description of the 
requirement, including the citation of the legislation which authorizes 
the program or project, and a statement as to the intended purpose/use 
of the proposed contract.
    (2) Period of performance. The number of months (or other time 
period) required for total performance and, if applicable, for each 
phase of work indicated in the statement of work, as well as the 
proposed starting date.
    (3) Estimated cost and funds citation. An estimate of the total cost 
of the proposed contract and, if applicable, the estimate for each phase 
indicated in the statement of work. The project officer must provide a 
cost breakdown of all contributing cost factors, an estimate of the 
technical staff hours, direct material, subcontracting, travel, etc., 
and may consult with contracting and cost advisory personnel in 
developing this information. This section must include the certification 
of funds availability for the proposed acquisition, along with the 
appropriation and accounting information citations. When funds for the 
proposed acquisition are not currently available for obligation but are 
anticipated, a statement of intent to commit funds from the financial 
management officer shall be included in lieu of the certification of 
funds availability. (Contracts cannot be awarded unless funds are 
available, but see FAR 32.703-2).
    (4) Specification, purchase description, or statement or work. A 
description of the work to be performed that may be in the form of a 
specification, purchase description, or statement of work. Guidance 
concerning the statement of work and its contents is contained in 
307.7106. Use of the specification is primarily limited to supply or 
service contracts where the material end item or service to be delivered 
is well defined by the Government. To the maximum extent possible, 
requirements should be defined as performance-based statements of work 
that focus on outcomes or results. If the RFC for a service contract is 
not utilizing a performance-based statement of work, with associated 
measures and a quality surveillance plan, the rationale for this 
determination must be documented. If a performance-based service 
contract is utilized, the RFC must detail the performance standards that 
must be met, the quality surveillance plan that will be implemented and 
the performance incentives to be used, if applicable.
    (5) Schedule of deliverables/reporting requirements. A description 
of what is to be delivered, including, if applicable, technical and 
financial progress reports and any final report, and the required date 
of delivery for each deliverable. Reporting requirements should be 
tailored to the instant acquisition and should not be unnecessarily 
extensive or detailed. All delivery and reporting requirements shall 
include the quantities, the place of delivery, and time of delivery.

[[Page 22]]

    (6) Sources for solicitation. A list of known potential sources by 
name, size, type of ownership, and mailing address. The project officer 
is encouraged to use trade and professional journals and publications 
and conduct a thorough market research to identify new prospective 
sources to supplement the list of known sources. Efforts to identify 
set-aside possibilities, e.g., 8(a), HUBZone, and small business, and 
efforts to identify sources such as small disadvantaged and women-owned 
small businesses must be documented.
    (7) Project officer and alternate. The project officer's name, 
title, organization, mailing address, and telephone number, along with 
the same data for the project officer's alternate, and a statement that 
these individuals have completed the Department's project officer 
training course (see 307.l70)
    (b) The RFC must include, if applicable to the acquisition:
    (1) Background and need. The background, history, and necessity for 
the proposed contract. This section is to include prior, present, and 
planned efforts by the program office in the same or related areas, and 
a description of efforts by other departmental activities and Federal 
agencies in the same or related program areas, if known. In addition, 
specific project information, such as the relevance or contribution to 
overall program objectives, reasons for the need, priority, and project 
overlap are to be provided.
    (2) Reference materials. A list, by title and description, of study 
reports, plans, drawings, and other data to be made available to 
prospective offerors for use in preparation of proposals and/or the 
contractor for use in performance of the contract. The project officer 
must indicate whether this material is currently available or when it 
will be available, and how it may be accessed by potential offerors.
    (3) Technical evaluation criteria and instructions. Technical 
evaluation criteria, which have been developed based on the requirements 
of the specific project, and any instructions and information which will 
assist in the preparation of prospective offerors' technical proposals. 
Evaluation factors may include understanding of the problem, technical 
approach, experience, personnel, facilities, etc. Criteria areas 
discussed in the statement of work and the relative order of importance 
or weights assigned to each of these areas for technical evaluation 
purposes must be identified.
    (4) Special program clearances or approvals. Any required clearance 
or approval. The following special program clearances or approvals 
should be reviewed for applicability to each acquisition. The ones which 
are applicable should be addressed during the planning discussions 
between the project officer and contracting officer/contract specialist 
(see 307.104(f)) and immediate action should be initiated by the project 
officer to obtain the necessary clearances or approvals. Comprehensive 
checklists of these and any OPDIV special approvals, clearances, and 
requirements shall be provided for reference purposes to program offices 
by the servicing contracting activity. If the approval or clearance has 
been requested and is being processed at the time of RFC submission, a 
footnote to this effect, including all pertinent details, must be 
included in this section.
    (i) Commercial activities. (OMB Circular No. A-76). A request for 
contract (RFC) must contain a statement as to whether the proposed 
solicitation is or is not to be used as part of an OMB Circular No. A-76 
cost comparison. (See General Administration Manual (GAM) Chapter 18-10; 
FAR subpart 7.3, subpart 307.3; OMB Circular No. A-76.)
    (ii) Printing. The acquisition of printing and high volume 
duplicating by contract is prohibited unless it is authorized by the 
Joint Committee on Printing of the U.S. Congress. Procedures to be 
followed are contained in the ``Government Printing and Binding 
Regulations'' and the HHS Printing Management Manual and FAR subpart 
8.8.
    (iii) Paperwork Reduction Act. Under the Paperwork Reduction Act of 
1995, a Federal agency shall not collect information or sponsor the 
collection of information from ten or more persons (other than Federal 
employees acting within the scope of their employment) unless, in 
advance, the agency has submitted a request for Office of Management and 
Budget (OMB) review, to the OMB, and the OMB has approved the

[[Page 23]]

proposed collection of information. Procedures for the approval may be 
obtained by contacting the OPDIV reports clearance officer. (See 5 CFR 
part 1320).
    (iv) Publications. All projects that will result in contracts which 
include publications development (print products, electronic bulletin 
boards, posting on the internet) require review and approval by the 
Office of the Assistant Secretary for Public Affairs (OASPA). Form HHS-
615, Publication Planning and Clearance Request, must be forwarded to 
OASPA through the OPDIV public affairs officer. Publications are defined 
in Chapter 5-00-15 of the Public Affairs Management Manual.
    (v) Public affairs services. Projects for the acquisition of public 
affairs services in excess of $5,000 must be submitted to the Office of 
the Assistant Secretary for Public Affairs (OASPA) for review and 
approval on Form HHS-524, Request for Public Affairs Services Contract.
    (vi) Audiovisual. All projects which will result in contracts which 
include audiovisuals, regardless of the audio, video, or audiovisual 
medium employed, require review and approval by the Office of the 
Assistant Secretary for Public Affairs (OASPA). Form HHS-524A, 
Publication Planning and Clearance Request, must be forwarded to OASPA 
through the OPDIV public affairs officer. Audiovisuals are defined in 
chapter 6-00-15 of the Public Affairs Management Manual.
    (vii) Privacy Act (5 U.S.C. 552a). Whenever the Department contracts 
for the design, development, operation, or maintenance of a system of 
records on individuals on behalf of the Department to accomplish a 
departmental function, the Privacy Act is applicable. The program 
official, after consultation with the activity's Privacy Act Coordinator 
and the Office of General Counsel, as necessary, shall include a 
statement in the request for contract as to the applicability of the 
Act. Whenever an acquisition is subject to the Act, the program official 
prepares a ``system notice'' and has it published in the Federal 
Register. (See HHS Privacy Act regulation, 45 CFR part 5b; FAR subpart 
24.1 and subpart 324.1.)
    (viii) Foreign research. All foreign research contract projects to 
be conducted in a foreign country and financed by HHS funds (U.S. 
dollars) must have clearance by the Department of State with respect to 
consistency with foreign policy objectives. This clearance should be 
obtained prior to negotiation. Procedures for obtaining this clearance 
are set forth in the HHS General Administration Manual, Chapter 20-60.
    (5) Identification and disposition of data. Identification of the 
data expected to be generated by the acquisition and an indication of 
whether the data are to be delivered to the Department or to be retained 
by the contractor is required. The project officer must also include 
information relative to the use, maintenance, disclosure, and 
disposition of data. The project officer must include a statement as to 
whether or not another acquisition, based upon the data generated by the 
proposed acquisition, is anticipated.
    (6) Government property. If known, the type of Government property, 
individual items, and quantities of Government property to be furnished 
to, or allowed to be acquired by, the resultant contractor should be 
indicated. The project officer must specify when the Government property 
is to be made available.
    (7) Special terms and conditions. Any suggested special terms and 
conditions not already covered in the statement of work or the 
applicable contract general provisions is required.
    (8) Justification for other than full and open competition. If the 
proposed acquisition is to be awarded using other than full and open 
competition, a justification prepared in accordance with FAR subpart 6.3 
and subpart 306.3 is required.



Sec. 307.7106  Statement of work.

    (a) General. A statement of work (SOW) differs from a specification 
and purchase description primarily in that it describes work or services 
to be performed in reaching an end result rather than a detailed, well 
defined description or specification of the end product. The SOW may 
enumerate or describe the methods (statistical, clinical, laboratory, 
etc.) that will be used.

[[Page 24]]

However, it is preferable for the offeror to propose the method of 
performing the work. The SOW should specify the desired results, 
functions, or end items without telling the offeror what has to be done 
to accomplish those results unless the method of performance is critical 
or required for the successful performance of the contract. The SOW 
should be clear and concise and must completely define the 
responsibilities of the Government and the contractor. The SOW should be 
worded so as to make more than one interpretation virtually impossible 
because it has to be read and interpreted by persons of varied 
backgrounds, such as attorneys, contracting personnel, cost estimators, 
accountants, scientists, educators, functional specialists, etc. The SOW 
must clearly define the obligations of both the contractor and the 
Government so as to protect the interests of both. Ambiguous statements 
of work can create unsatisfactory performance, delays, and disputes, and 
can result in higher costs.
    (b) Term (level of effort) vs. completion work statement. Careful 
distinctions must be drawn between term (level of effort) SOWs, which 
essentially require the furnishing of technical effort and which may 
include a report thereof, and completion type work statements, which 
require development of tangible items designed to meet specific 
performance and/or design characteristics. (See FAR 16.306(d) for 
distinction).
    (1) Term (or level of effort). A term or level of effort type SOW is 
appropriate for research where one seeks to discover the feasibility of 
later development, or to gather general information. A term or level of 
effort type SOW may only specify that some number of labor-hours be 
expended on a particular course of research, or that a certain number of 
tests be run, without reference to any intended conclusion.
    (2) Completion. A completion type SOW is appropriate to development 
work where the feasibility of producing an end item is already known. A 
completion type SOW may describe what is to be achieved through the 
contracted effort, such as development of new methods, new end items, or 
other tangible results.
    (c) Phasing. Individual research, development, or demonstration 
projects frequently lie well beyond the present state of the art and 
entail procedures and techniques of great complexity and difficulty. 
Under these circumstances, a contractor, no matter how carefully 
selected, may be unable to deliver the desired result. Moreover, the job 
of evaluating the contractor's progress is often difficult. Such a 
contract is frequently phased and often divided into stages of 
accomplishment, each of which must be completed and approved before the 
contractor may proceed to the next. Phasing makes it necessary to 
develop methods and controls, including reporting requirements for each 
phase of the contract and criteria for evaluation of the report 
submitted, that will provide, at the earliest possible time, appropriate 
data for making decisions relative to future phases. A phased contract 
may include stages of accomplishment such as research, development, and 
demonstration. Within each phase, there may be a number of tasks which 
should be included in the SOW. When phases of work can be identified, 
the SOW will provide for phasing and the request for proposals will 
require the submission of proposed costs by phases. The resultant 
contract will reflect costs by phases, require the contractor to 
identify incurred costs by phases, establish delivery schedules by 
phase, and require the written acceptance of each phase. The provisions 
of the Limitation of Cost clause shall apply to the estimated cost of 
each phase. Contractors shall not be allowed to incur costs for phases 
which are dependent upon successful completion of earlier phases until 
written acceptance of the prior work is obtained from the contracting 
officer.
    (d) Elements of the SOW. The elements of the SOW will vary with the 
objective, complexity, size, and nature of the acquisition. In general, 
it should cover the following matters as appropriate.
    (1) A general description of the required objectives and desired 
results. Initially, a broad, nontechnical statement of the nature of the 
work to be performed. This should summarize the actions to be performed 
by the contractor and the results that the Government expects.

[[Page 25]]

    (2) Background information helpful to a clear understanding of the 
requirements and how they evolved. Include a brief historical summary as 
appropriate and the relationship to overall program objectives.
    (3) A detailed description of the technical requirements. A 
comprehensive description of the work to be performed to provide 
whatever details are necessary for prospective offerors to submit 
meaningful proposals.
    (4) Subordinate tasks or types of work. A listing of the various 
tasks or types of work (it may be desirable in some cases to indicate 
that this is not all-inclusive). The degree of task breakout is directly 
dependent on the size and complexity of the work to be performed and the 
logical groupings. A single cohesive task should not be broken out 
merely to conform to a format. Indicate whether the tasks are sequential 
or concurrent for offeror planning purposes.
    (5) Reference material. All reference material to be used in the 
conduct of the project that tells how the work is to be carried out must 
be identified. Applicability should be explained, and a statement made 
as to where the material can be obtained.
    (6) Level of effort. When a level of effort is required, the number 
and type of personnel required should be stated. If known, the type and 
degree of expertise should be specified.
    (7) Special requirements. (as applicable). An unusual or special 
contractual requirement, which would impact on contract performance, 
should be included as a separate section.
    (8) Deliverables reporting requirements. All deliverables and/or 
reports must be clearly and completely described.



Sec. 307.7107  Review.

    Upon receipt of the RFC, the contracting officer shall review its 
contents to ensure that all pertinent information has been provided by 
the program office and that it includes an acceptable SOW. If pertinent 
information is missing or the SOW is inadequate, the contracting officer 
shall obtain or clarify the information as soon as possible so that the 
acquisition schedule can be met. If the program office delays furnishing 
the information or clarification, the contracting officer should notify 
the head of the sponsoring program office, in writing, of the possible 
slippage in the acquisition schedule and the need for an expeditious 
remedy. The contracting officer should also notify the chief of the 
contracting office. A program office's or project officer's continued 
failure to adhere to agreed on milestones should also be reported to the 
head of the contracting activity.

                   PART 309_CONTRACTOR QUALIFICATIONS

         Subpart 309.4_Debarment, Suspension, and Ineligibility

Sec.

Sec. 309.403  Definitions.

Sec. 309.404  List of Parties Excluded from Federal Procurement and 
          Nonprocurement Programs.

Sec. 309.405  Effect of listing.

Sec. 309.406  Debarment.

Sec. 309.406-3  Procedures.

Sec. 309.407  Suspension.

Sec. 309.407-3  Procedures.

Sec. 309.470  Reporting of suspected causes for debarment, suspension, 
          or the taking of evasive actions.

Sec. 309.470-1  Situations where reports are required.

Sec. 309.470-2  Contents of reports.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4231, Jan. 17, 2001, unless otherwise noted.

         Subpart 309.4_Debarment, Suspension, and Ineligibility



Sec. 309.403  Definitions.

    Acquiring agency's head or designee, as used in the FAR, shall mean, 
unless otherwise stated in this subpart, the head of the contracting 
activity. Acting in the capacity of the acquiring agency's head, the 
head of the contracting activity may make the required justifications or 
determinations, and take the necessary actions, specified in FAR 9.405, 
9.406 and 9.407 for his or her respective activity, but only after 
obtaining the written approval of the debarring or suspending official, 
as the case may be.
    Debarring official means the Assistant Secretary for Management and 
Budget, or his/her designee.

[[Page 26]]

    Initiating official means either the contracting officer, the head 
of the contracting activity, the Deputy Assistant Secretary for Grants 
and Acquisition Management, or the Inspector General.
    Suspending official means the Assistant Secretary for Management and 
Budget, or his/her designee.



Sec. 309.404  List of Parties Excluded from Federal Procurement and 
          Nonprocurement Programs.

    (c) The Office of Grants and Acquisition Management (OGAM) shall 
perform the actions required by FAR 9.404(c).
    (4) OGAM shall maintain all documentation submitted by the 
initiating official recommending the debarment or suspension action and 
all correspondence and other pertinent documentation generated during 
the OGAM review.



Sec. 309.405  Effect of listing.

    (a) The head of the contracting activity (HCA) (not delegable) may, 
with the written concurrence of the debarring or suspending official, 
make the determinations referenced in FAR 9.405(a), regarding contracts 
for their respective activities.
    (1) If a contracting officer considers it necessary to award a 
contract, or consent to a subcontract with a debarred or suspended 
contractor, the contracting officer shall prepare a determination, 
including all pertinent documentation, and submit it through acquisition 
channels to the head of the contracting activity. The documentation must 
include the date by which approval is required and a compelling reason 
for the proposed action. Some examples of circumstances that may 
constitute a compelling reason for the award to, or consent to a 
subcontract with, a debarred or suspended contractor include:
    (i) The property or services to be acquired are available only from 
the listed contractor;
    (ii) The urgency of the requirement dictates that the Department 
deal with the listed contractor; or
    (iii) There are other compelling reasons which require business 
dealings with the listed contractor.
    (2) If the HCA decides to approve the requested action, he/she shall 
request the concurrence of the debarring or suspending official and, if 
given, shall inform the contracting officer in writing of the decision 
within the required time period.



Sec. 309.406  Debarment.



Sec. 309.406-3  Procedures.

    (a) Investigation and referral. Whenever an apparent cause for 
debarment becomes known to an initiating official, that person shall 
prepare a report incorporating the information required by 309.470-2, if 
known, and forward it through appropriate channels with a written 
recommendation, to the debarring official. Contracting officers shall 
forward their reports in accordance with 309.470-1. The debarring 
official shall initiate an investigation through such means as he/she 
deems appropriate.
    (b) Decisionmaking process. The debarring official shall review the 
results of the investigation, if any, and make a written determination 
whether or not debarment procedures are to be commenced. A copy of the 
determination shall be promptly sent through appropriate channels to the 
initiating official, and the contracting officer, if necessary. If the 
debarring official determines to commence debarment procedures, he/she 
shall, after consultation with the Office of the General Counsel, notify 
the contractor in accordance with FAR 9.406-3(c). If the proposed action 
is not based on a conviction or judgement and the contractor's 
submission in response to the notice raises a genuine dispute over facts 
material to the proposed debarment, the debarring official shall arrange 
for fact-finding hearings and take the necessary action specified in FAR 
9.406-3(b)(2). The debarring official shall also ensure that written 
findings of facts are prepared, and shall base the debarment decisions 
on the facts as found, after considering information and argument 
submitted by the contractor and any other information in the 
administrative record. The Office of the General Counsel shall represent 
the Department at any fact-

[[Page 27]]

finding hearing and may present witnesses for HHS and question any 
witnesses presented by the contractor.



Sec. 309.407  Suspension.



Sec. 309.407-3  Procedures.

    (a) Investigation and referral. Whenever an apparent cause for 
suspension becomes known to an initiating official, that person shall 
prepare a report incorporating the information required by 309.470-2, if 
known, and forward it through appropriate channels, with a written 
recommendation, to the suspending official. Contracting officers shall 
forward their reports in accordance with 309.470-1. The suspending 
official shall initiate an investigation through such means as he/she 
deems appropriate.
    (b) Decisionmaking process. The suspending official shall review the 
results of the investigation, if any, and make a written determination 
whether or not suspension should be imposed. A copy of this 
determination shall be promptly sent through appropriate channels to the 
initiating official and the contracting officer, if necessary. If the 
suspending official determines to impose suspension, he/she shall, after 
consultation with the Office of the General Counsel, notify the 
contractor in accordance with FAR 9.407-3(c). If the action is not based 
on an indictment, and, subject to the provisions of FAR 9.407-3(b)(2), 
the contractor's submission in response to the notice raises a genuine 
dispute over facts material to the suspension, the suspending official 
shall, after suspension has been imposed, arrange for fact-finding 
hearings and take the necessary actions specified in FAR 9.407-3(b)(2).



Sec. 309.470  Reporting of suspected causes for debarment or suspension, 
          or the taking of evasive actions.



Sec. 309.470-1  Situations where reports are required.

    A report incorporating the information required by 309.470-2 shall 
be forwarded, in duplicate, by the contracting officer through 
acquisition channels to OGAM when:
    (a) A contractor has committed, or is suspected of having committed, 
any of the acts described in FAR 9.406-2 or FAR 9.407-2; or
    (b) A contractor is suspected of attempting to evade the 
prohibitions of debarment or suspension imposed under this subject, or 
any other comparable regulation, by changes of address, multiple 
addresses, formation of new companies, or by other devices.



Sec. 309.470-2  Contents of reports.

    Each report prepared under 309.470-1 shall be coordinated with the 
Office of the General Counsel and shall include the following 
information, where available:
    (a) Name and address of contractor.
    (b) Name of the principal officers, partners, owners, or managers.
    (c) All known affiliates, subsidiaries, or parent firms, and the 
nature of the affiliation.
    (d) Description of the contract or contracts concerned, including 
the contract number, and office identifying numbers or symbols, the 
amount of each contract, the amount paid the contractor and the amount 
still due, and the percentage of work completed and to be completed.
    (e) The status of vouchers.
    (f) Whether contract funds have been assigned pursuant to the 
Assignment of Claims Act, as amended, (31 U.S.C. 3727, 41 U.S.C. 15), 
and, if so assigned, the name and address of the assignee and a copy of 
the assignment.
    (g) Whether any other contracts are outstanding with the contractor 
or any affiliates, and, if so, the amount of the contracts, whether 
these funds have been assigned pursuant to the Assignment of Claims Act, 
as amended, (31 U.S.C. 3727, 41 U.S.C. 15), and the amounts paid or due 
on the contracts.
    (h) A complete summary of all available pertinent evidence.
    (i) A recommendation as to the continuation of current contracts.
    (j) An estimate of damages, if any, sustained by the Government as a 
result of the action of the contractor, including an explanation of the 
method used in making the estimate.
    (k) The comments and recommendations of the contracting officer and 
statements regarding whether the contractor should be suspended or 
debarred, whether any limitations

[[Page 28]]

should be applied to the action, and the period of any proposed 
debarment.
    (l) As an enclosure, a copy of the contract(s) or pertinent excerpts 
therefrom, appropriate exhibits, testimony or statements of witnesses, 
copies of assignments, and other relevant documentation or a written 
summary of any information for which documentation is not available.

[[Page 29]]



           SUBCHAPTER C_CONTRACTING METHODS AND CONTRACT TYPES

               PART 313_SIMPLIFIED ACQUISITION PROCEDURES

              Subpart 313.3_Simplified Acquisition Methods

Sec.

Sec. 313.301  Governmentwide commercial purchase card.

Sec. 313.303  Blanket Purchase Agreements (BPAs).

Sec. 313.303-5  Purchases under BPAs.

Sec. 313.305  Imprest funds and third party drafts.

Sec. 313.305-1  General.

Sec. 313.306  SF 44, Purchase Order--Invoice--Voucher.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source:  66 FR 4233, Jan. 17, 2001, unless otherwise noted.

              Subpart 313.3_Simplified Acquisition Methods.



Sec. 313.301  Governmentwide commercial purchase card.

    (b) The Department has issued general guidance concerning the use of 
governmentwide commercial purchase cards, and has authorized the OPDIVs 
to establish procedures for the use, administrative and management 
controls, and training necessary to comply with FAR 13.301.



Sec. 313.303  Blanket Purchase Agreements (BPAs).



Sec. 313.303-5  Purchases under BPAs.

    (e)(5) Delivery documents, invoices, etc., signed by the Government 
employee receiving the item or service will be forwarded to the fiscal 
office or other paying office as designated by the OPDIV. Payment will 
be made on the basis of the signed document, invoice, etc. Contracting 
offices will ensure that established procedures allowing for 
availability of funds are in effect prior to placement of orders.



Sec. 313.305  Imprest funds and third party drafts.



Sec. 313.305-1  General.

    Requests to establish imprest funds shall be made to the responsible 
fiscal office. At larger activities where the cashier may not be 
conveniently located near the purchasing office, a Class C Cashier may 
be installed in the purchasing office. Documentation of cash purchases 
shall be in accordance with instructions contained in the HHS Voucher 
Audit Manual Part 1, Chapter 1-10.



Sec. 313.306  SF 44, Purchase Order--Invoice--Voucher.

    (d) Since the Standard Form (SF) 44 is an accountable form, a record 
shall be maintained of serial numbers of the form, to whom issued, and 
date issued. SF 44's shall be kept under adequate lock and key to 
prevent unauthorized use. A reservation of funds shall be established to 
cover total anticipated expenditures prior to use of the SF 44.

                         PART 314_SEALED BIDDING

                   Subpart 314.2_Solicitation of Bids

Sec.

Sec. 314.202  General rules for solicitation of bids.

Sec. 314.202-7  Facsimile bids.

Sec. 314.213  Annual submission of representations and certifications.

           Subpart 314.4_Opening of Bids and Award of Contract


Sec. 314.404  Rejection of bids.

Sec. 314.404-1  Cancellation of invitations after opening.

Sec. 314.407  Mistakes in bids.

Sec. 314.407-3  Other mistakes disclosed before award.

Sec. 314.407-4  Mistakes after award.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4233, Jan. 17, 2001, unless otherwise noted.

[[Page 30]]

                   Subpart 314.2_Solicitation of Bids



Sec. 314.202  General rules for solicitation of bids.



Sec. 314.202-7  Facsimile bids.

    If the head of the contracting activity (HCA) (not delegable) has 
determined that the contracting activity will allow use of facsimile 
bids and proposals, the HCA shall prescribe internal procedures, in 
accordance with the FAR, to ensure uniform processing and control.



Sec. 314.213  Annual submission of representations and certifications.

    Each HCA (not delegable) shall determine whether the contracting 
activity will allow use of the annual submission of representations and 
certifications by bidders.

           Subpart 314.4_Opening of Bids and Award of Contract



Sec. 314.404  Rejection of bids.



Sec. 314.404-1  Cancellation of invitations after opening.

    The chief of the contracting office (CCO) (not delegable) shall make 
the determinations required to be made by the agency head in FAR 14.404-
1.



Sec. 314.407  Mistakes in bids.



Sec. 314.407-3  Other mistakes disclosed before award.

    (e) Authority has been delegated to the Departmental Protest Control 
Officer, Office of Acquisition Management, Office of Grants and 
Acquisition Management, to make administrative determinations in 
connection with mistakes in bid alleged after opening and before award. 
This authority may not be redelegated.
    (f) Each proposed determination shall have the concurrence of the 
Chief, Business Law Branch, Business and Administrative Law Division, 
Office of General Counsel.
    (i) Doubtful cases shall not be submitted by the contracting officer 
directly to the Comptroller General, but shall be submitted to the 
Departmental Protest Control Officer.



Sec. 314.407-4  Mistakes after award.

    (c) Authority has been delegated to the Departmental Protest Control 
Officer to make administrative determinations in connection with 
mistakes in bid alleged after award. This authority may not be 
redelegated.
    (d) Each proposed determination shall have the concurrence of the 
Chief, Business Law Branch, Business and Administrative Law Division, 
Office of the General Counsel.

                   PART 315_CONTRACTING BY NEGOTIATION

   Subpart 315.2_Solicitation and Receipt of Proposals and Information

Sec.

Sec. 315.204  Contract format.

Sec. 315.204-5  Part IV--Representations and instructions.

Sec. 315.208  Submission, modification, revision, and withdrawal of 
          proposals.

Sec. 315.209  Solicitation provisions and contract clauses.

                     Subpart 315.3_Source Selection


Sec. 315.305  Proposal evaluation.

Sec. 315.306  Exchanges with offerors after receipt of proposals.

Sec. 315.307  Proposal revisions.

Sec. 315.370  Finalization of details with the selected source.

Sec. 315.371  Contract preparation and award.

Sec. 315.372  Preparation of negotiation memorandum.

                     Subpart 315.4_Contract Pricing


Sec. 315.404  Proposal analysis.

Sec. 315.404-2  Information to support proposal analysis.

Sec. 315.404-4  Profit.

                   Subpart 315.6_Unsolicited Proposals


Sec. 315.605  Content of unsolicited proposals.

Sec. 315.606  Agency procedures.

Sec. 315.606-1  Receipt and initial review.

Sec. 315.609  Limited use of data.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4233, Jan. 17, 2001, unless otherwise noted.

[[Page 31]]

   Subpart 315.2_Solicitation and Receipt of Proposals and Information



Sec. 315.204  Contract format.



Sec. 315.204-5  Part IV--Representations and instructions.

    (a) Section K, Representations, certifications, and other statements 
of offerors.
    (1) This section shall begin with the following and continue with 
the applicable representations and certifications:

    To Be Completed by the Offeror: (The Representations and 
Certifications must be executed by an individual authorized to bind the 
offeror.) The offeror makes the following Representations and 
Certifications as part of its proposal (check or complete all 
appropriate boxes or blanks on the following pages).

_______________________________________________________________________
(Name of Offeror)

_______________________________________________________________________
(RFP No.)

_______________________________________________________________________
(Signature of Authorized Individual)

_______________________________________________________________________
(Date)

_______________________________________________________________________
(Typed Name of Authorized Individual)
    Note: The penalty for making false statements in offers is 
prescribed in 18 U.S.C. 1001.

    (c) Section M, Evaluation factors for award. (1) General. (i) The 
evaluation factors must be developed by the project officer and 
submitted to the contracting officer in the request for contract (RFC) 
for inclusion in the request for proposal (RFP). Development of these 
factors and the assignment of the relative importance or weight to each 
require the exercise of judgment on a case-by-case basis because they 
must be tailored to the requirements of the individual acquisition. 
Since the factors will serve as a standard against which all proposals 
will be evaluated, it is imperative that they be chosen carefully to 
emphasize those considered to be critical in the selection of a 
contractor.
    (ii) The finalized evaluation factors cannot be changed except by a 
formal amendment to the RFP issued by the contracting officer. No 
factors other than those set forth in the RFP shall be used in the 
evaluation of proposals.
    (2) Review of evaluation factors. (i) The evaluation factors should 
be reviewed by the contracting officer in terms of the work statement. 
This review is not intended to dictate technical requirements to the 
program office or project officer, but rather to ensure that the 
evaluation factors are clear, concise, and fair so that all potential 
offerors are fully aware of the bases for proposal evaluation and are 
given an equal opportunity to compete.
    (ii) The project officer and the contracting officer should then 
review the evaluation factors together to ascertain the following:
    (A) The factors are described in sufficient detail to provide the 
offerors (and evaluators) with a total understanding of the factors to 
be involved in the evaluation process;
    (B) The factors address the key programmatic concerns which the 
offerors must be aware of in preparing proposals;
    (C) The factors are specifically applicable to the instant 
acquisition and are not merely restatements of factors from previous 
acquisitions which are not relevant to this acquisition; and
    (D) The factors are selected to represent only the significant areas 
of importance which must be emphasized rather than a multitude of 
factors. (All factors tend to lose importance if too many are included. 
Using too many factors will prove as detrimental as using too few.)
    (3) Examples of topics that form a basis for evaluation factors. 
Typical examples of topics that form a basis for the development of 
evaluation factors are listed in the following paragraphs. These 
examples are intended to assist in the development of actual evaluation 
factors for a specific acquisition and should only be used if they are 
applicable to that acquisition. They are not to be construed as actual 
examples of evaluation factors to be included in the RFP.
    (i) Understanding of the problem and statement of work:
    (ii) Method of accomplishing the objectives and intent of the 
statement of work;
    (iii) Soundness of the scientific or technical approach for 
executing the requirements of the statement of work

[[Page 32]]

(to include, when applicable, preliminary layouts, sketches, diagrams, 
other graphic representations, calculations, curves, and other data 
necessary for presentation, substantiation, justification, or 
understanding of the approach);
    (iv) Special technical factors, such as experience or pertinent 
novel ideas in the specific branch of science or technology involved;
    (v) Feasibility and/or practicality of successfully accomplishing 
the requirements (to include a statement and discussion of anticipated 
major difficulties and problem areas and recommended approaches for 
their resolution);
    (vi) Availability of required special research, test, and other 
equipment or facilities;
    (vii) Managerial capability (ability to achieve delivery or 
performance requirements as demonstrated by the proposed use of 
management and other personnel resources, and to successfully manage the 
project, including subcontractor and/or consultant efforts, if 
applicable, as evidenced by the management plan and demonstrated by 
previous experience);
    (viii) Availability, qualifications, experience, education, and 
competence of professional, technical, and other personnel, to include 
proposed subcontractors and consultants (as evidenced by resumes, 
endorsements, and explanations of previous efforts);
    (ix) Soundness of the proposed staff time or labor hours, propriety 
of personnel classifications (professional, technical, others), 
necessity for type and quantity of material and facilities proposed, 
validity of proposed subcontracting, and necessity of proposed travel;
    (x) Quality of offeror's past performance on recent projects of 
similar size and scope; and
    (xi) Extent of proposed participation of small disadvantaged 
business concerns in performance of the contract.



Sec. 315.208  Submission, modification, revision, and withdrawal of 
          proposals.

    (b) When the head of the contracting activity (HCA) for a health 
agency determines that certain classes of biomedical or behavioral 
research and development acquisitions should be subject to conditions 
other than those specified in FAR 52.215-1(c)(3), the HCA may authorize 
the use of the provision at 352.215-70 in addition to the provision at 
FAR 52.215-1. This is an authorized deviation.
    (2) When the provision at 352.215-70 is included in the solicitation 
and a proposal is received after the exact time specified for receipt, 
the contracting officer, with the assistance of cost and technical 
personnel, shall make a written determination as to whether the proposal 
meets the requirements of the provision at 352.215-70 and, therefore, 
can be considered.



Sec. 315.209  Solicitation provisions and contract clauses.

    (a) Paragraph (e) of the provision at 352.215-1 shall be used in 
place of that specified at FAR 52.215-1(e). This is an authorized 
deviation.
    (g) If the head of the contracting activity (HCA)(not delegable) has 
determined that the contracting activity will allow the use of the 
annual submission of representations and certifications by offerors, the 
provisions of FAR 14.213 shall be followed.

                     Subpart 315.3_Source Selection



Sec. 315.305  Proposal evaluation.

    (a)(1) Cost or price evaluation. The contracting officer shall 
evaluate business proposals adhering to the requirements for cost or 
price analysis included in FAR 15.404. The contracting officer must 
determine the extent of analysis in each case depending on the amount of 
the proposal, the technical complexity, and related cost or price. The 
contracting officer should request the project officer to analyze items 
such as the number of labor hours proposed for various labor categories; 
the mix of labor hours and categories of labor in relation to the 
technical requirements of the project; the kinds and quantities of 
material, equipment, and supplies; types, numbers and hours/days of 
proposed consultants; logic of proposed subcontracting; analysis of the 
travel proposed including number of trips, locations, purpose, and 
travelers; and kinds and quantities of information technology. The 
project officer

[[Page 33]]

shall provide his/her opinion as to whether these elements are necessary 
and reasonable for efficient contract performance. Exceptions to 
proposed elements shall be supported by adequate rationale to allow for 
effective negotiations or award if discussions are not conducted. The 
contracting officer should also request the assistance of a cost/price 
analyst when considered necessary. In all cases, the negotiation 
memorandum must include the rationale used in determining that the price 
or cost is fair and reasonable.
    (2) Past performance evaluation. When evaluating past performance, 
the contracting officer is responsible for conducting reference checks 
to obtain information concerning the performance history of offerors. 
The contracting officer may require the assistance of the project 
officer as well as other Government technical personnel in performing 
this function.
    (3) Technical evaluation.
    (i) Technical evaluation plan.
    (A) A technical evaluation plan may be required by the contracting 
officer, at his/her discretion, when an acquisition is sufficiently 
complex as to warrant a formal plan.
    (B) The technical evaluation plan should include at least the 
following:
    (1) A list of recommended technical evaluation panel members, their 
organizations, a list of their major consulting clients (if applicable), 
their qualifications, and curricula vitae (if applicable);
    (2) A justification for using non-Government technical evaluation 
panel members. (Justification is not required if non-Government 
evaluators will be used in accordance with standard contracting activity 
procedures or policies);
    (3) A statement that there is no apparent or actual conflict of 
interest regarding any recommended panel member;
    (4) A copy of each rating sheet, approved by the contracting 
officer, to be used to assure consistency with the evaluation criteria; 
and
    (5) A brief description of the general evaluation approach.
    (C) The technical evaluation plan must be signed by an official 
within the program office in a position at least one level above the 
project officer, or in accordance with contracting activity procedures.
    (D) The technical evaluation plan should be submitted to the 
contracting officer for review and approval before the solicitation is 
issued. The contracting officer shall make sure that the significant 
factors and subfactors relating to the evaluation are reflected in the 
evaluation criteria when conducting the review of the plan.
    (ii) Technical evaluation panel.
    (A) General. (1) A technical evaluation panel is required for all 
acquisitions subject to this subpart which are expected to exceed 
$500,000 and in which technical evaluation is considered a key element 
in the award decision. The contracting officer has the discretion to 
require a technical evaluation panel for acquisitions not exceeding 
$500,000 based on the complexity of the acquisition.
    (2) The technical evaluation process requires careful consideration 
regarding the size, composition, expertise, and function of the 
technical evaluation panel. The efforts of the panel can result in the 
success or failure of the acquisition.
    (B) Role of the project officer. (1) The project officer is the 
contracting officer's technical representative for the acquisition 
action. The project officer may be a voting member of the technical 
evaluation panel, and may also serve as the chairperson of the panel, 
unless he/she is prohibited by law or contracting activity procedures to 
do so.
    (2) The project officer is responsible for recommending panel 
members who are knowledgeable in the technical aspects of the 
acquisition and who are competent to identify strengths and weaknesses 
of the various proposals. The program training requirements specified in 
307.170 must be adhered to when selecting prospective panel members 
(government employees).
    (3) The project officer shall ensure that persons possessing 
expertise and experience in addressing issues relative to sex, race, 
national origin, and handicapped discrimination are included as panel 
members in acquisitions which address those issues. The intent is to 
balance the composition of the panel so

[[Page 34]]

that qualified and concerned individuals may provide insight to other 
panel members regarding ideas for, and approaches to be taken in, the 
evaluation of proposals.
    (4) The project officer is to submit the recommended list of panel 
members to an official within the program office in a position at least 
one level above the project officer, or in accordance with contracting 
activity procedures. This official will review the recommendations and 
select the chairperson.
    (5) The project officer shall arrange for adequate and secure 
working space for the panel.
    (C) Role of the contracting officer. (1) The term ``contracting 
officer,'' as used in this subpart, may be the contracting officer or 
his/her designated representative within the contracting office.
    (2) The contracting officer shall not serve as a member of the 
technical evaluation panel but should be available to:
    (i) Address the initial meeting of the technical evaluation panel;
    (ii) Provide assistance to the evaluators as required; and
    (iii) Ensure that the scores adequately reflect the written 
technical report comments.
    (D) Conflict of interest. (1) If a panel member has an actual or 
apparent conflict of interest related to a proposal under evaluation, 
he/she shall be removed from the panel and replaced with another 
evaluator. If a suitable replacement is not available, the panel shall 
perform the review without a replacement.
    (2) For the purposes of this subpart, conflicts of interest are 
defined in the Standards of Ethical Conduct for Employees of the 
Executive Branch (5 CFR part 2635), Supplemental Standards of Ethical 
Conduct for Employees of the Department of Health and Human Services (5 
CFR part 5501), and the Procurement Integrity Act. For outside 
evaluators serving on the technical evaluation panel, see paragraph 
(a)(3)(ii)(F) of this section.
    (E) Continuity of evaluation process. (1) The technical evaluation 
panel is responsible for evaluating the original proposals, making 
recommendations to the chairperson regarding weaknesses and deficiencies 
of proposals, and, if required by the contracting officer, assisting the 
contracting officer during communications and discussions, and reviewing 
supplemental, revised and/or final proposal revisions. To the extent 
possible, the same evaluators should be available throughout the entire 
evaluation and selection process to ensure continuity and consistency in 
the treatment of proposals. The following are examples of circumstances 
when it would not be necessary for the technical evaluation panel to 
evaluate revised proposals submitted during the acquisition:
    (i) The answers to questions do not have a substantial impact on the 
proposal;
    (ii) Final proposal revisions are not materially different from the 
original proposals; or
    (iii) The rankings of the offerors are not affected because the 
revisions to the proposals are relatively minor.
    (2) The chairperson, with the concurrence of the contracting 
officer, may decide not to have the panel evaluate the revised 
proposals. Whenever this decision is made, it must be fully documented 
by the chairperson and approved by the contracting officer.
    (3) When technical evaluation panel meetings are considered 
necessary by the contracting officer, the attendance of evaluators is 
mandatory. When the chairperson determines that an evaluator's failure 
to attend the meetings is prejudicial to the evaluation, the chairperson 
shall remove and/or replace the individual after discussing the 
situation with the contracting officer and obtaining his/her concurrence 
and the approval of the official responsible for appointing the panel 
members.
    (4) Whenever continuity of the evaluation process is not possible, 
and either new evaluators are selected or a reduced panel is decided 
upon, each proposal which is being reviewed at any stage of the 
acquisition shall be reviewed at that stage by all members of the 
revised panel unless it is impractical to do so because of the receipt 
of an unusually large number of proposals.
    (F) Use of outside evaluators. (1) The National Institutes of Health 
(NIH) and

[[Page 35]]

the Substance Abuse and Mental Health Services Administration (SAMHSA) 
are required to have a peer review of research and development contracts 
in accordance with Public Law 93-352 as amended by Public Law 94-63; 42 
U.S.C. 289 a and 42 U.S.C. 290aa-3 respectively. This legislation 
requires peer review of projects and proposals, and not more than one-
fourth of the members of a peer review group may be officers or 
employees of the United States. NIH and SAMHSA are therefore exempt from 
the provisions of 315.305(a)(3)(ii) to the extent that 42 U.S.C. 289a 
and 290aa-3 apply. Conflicts of interest are addressed at 42 CFR part 
52h. Other agencies subject to statutory scientific peer review 
requirements are also exempt from the requirements of paragraph 
(a)(3)(ii) of this section to the extent that these requirements are 
inconsistent with their legislative requirements.
    (2) In general, decisions to disclose proposals outside the 
Government for evaluation purposes shall be made by the official 
responsible for appointing panel members for the acquisition, after 
consultation with the contracting officer and in accordance with 
operating division procedures. The decision to disclose either a 
solicited or unsolicited proposal outside the Government for the purpose 
of obtaining an evaluation shall take into consideration the avoidance 
of organizational conflicts of interest and any competitive relationship 
between the submitter of the proposal and the prospective evaluator(s).
    (3) When it is determined to disclose a solicited proposal outside 
the Government for evaluation purposes, the following or similar 
conditions shall be included in the written agreement with evaluator(s) 
prior to disclosure:

                   Conditions for Evaluating Proposals

    The evaluator agrees to use the data (trade secrets, business data, 
and technical data) contained in the proposal only for evaluation 
purposes.
    The foregoing requirement does not apply to data obtained from 
another source without restriction.
    Any notice or legend placed on the proposal by either the Department 
or the submitter of the proposal shall be applied to any reproduction or 
abstract provided to the evaluator or made by the evaluator. Upon 
completion of the evaluation, the evaluator shall return the Government 
furnished copy of the proposal or abstract, and all copies thereof, to 
the Departmental office which initially furnished the proposal for 
evaluation.
    Unless authorized by the Department's initiating office, the 
evaluator shall not contact the submitter of the proposal concerning any 
aspects of its contents.
    The evaluator is obligated to obtain commitments from its employees 
and subcontractors, as necessary, to effect the purposes of these 
conditions.

    (iii) Receipt of proposals.
    (A) After the closing date set by the solicitation for the receipt 
of proposals, the contracting officer will use a transmittal memorandum 
to forward the technical proposals to the project officer or chairperson 
for evaluation. The business proposals will be retained by the 
contracting officer for evaluation.
    (B) The transmittal memorandum shall include at least the following:
    (1) A list of the names of the organizations submitting proposals;
    (2) A reference to the need to preserve the integrity of the source 
selection process;
    (3) A statement that only the contracting officer is to conduct 
discussions.
    (4) A requirement for a technical evaluation report in accordance 
with paragraph (a)(3)(vi) of this section; and
    (5) The establishment of a date for receipt of the technical 
evaluation report.
    (iv) Convening the technical evaluation panel.
    (A) Normally, the technical evaluation panel will convene to 
evaluate the proposals. However, there may be situations when the 
contracting officer determines that it is not feasible for the panel to 
convene. Whenever this decision is made, care must be taken to assure 
that the technical review is closely monitored to produce acceptable 
results.
    (B) When a panel is convened, the chairperson is responsible for the 
control of the technical proposals provided to him/her by the 
contracting officer for use during the evaluation process. The 
chairperson will generally distribute the technical proposals prior to

[[Page 36]]

the initial panel meeting and will establish procedures for securing the 
proposals whenever they are not being evaluated to insure their 
confidentiality. After the evaluation is complete, all proposals must be 
returned to the contracting officer by the chairperson.
    (C) The contracting officer shall address the initial meeting of the 
panel and state the basic rules for conducting the evaluation. The 
contracting officer shall provide written guidance to the panel if he/
she is unable to attend the initial panel meeting. The guidance should 
include:
    (1) Explanation of conflicts of interest;
    (2) The necessity to read and understand the solicitation, 
especially the statement of work and evaluation criteria, prior to 
reading the proposals;
    (3) The need for evaluators to restrict the review to only the 
solicitation and the contents of the technical proposals;
    (4) The need for each evaluator to review all the proposals;
    (5) The need to watch for ambiguities, inconsistencies, errors, and 
deficiencies which should be surfaced during the evaluation process;
    (6) An explanation of the evaluation process and what will be 
expected of the evaluators throughout the process;
    (7) The need for the evaluators to be aware of the requirement to 
have complete written documentation of the individual strengths and 
weaknesses which affect the scoring of the proposals; and
    (8) An instruction directing the evaluators that, until the award is 
made, information concerning the acquisition must not be disclosed to 
any person not directly involved in the evaluation process.
    (v) Rating and ranking of proposals. The evaluators will 
individually read each proposal, describe tentative strengths and 
weaknesses, and independently develop preliminary scores in relation to 
each evaluation factor set forth in the solicitation. After this has 
been accomplished, the evaluators shall discuss in detail the individual 
strengths and weakness described by each evaluator and, if possible, 
arrive at a common understanding of the major strengths and weaknesses 
and the potential for correcting each offeror's weakness(es). Each 
evaluator will score each proposal, and then the technical evaluation 
panel will collectively rank the proposals. Generally, ranking will be 
determined by adding the numerical scores assigned to the evaluation 
factors and finding the average for each offeror. The evaluators should 
then identify whether each proposal is acceptable or unacceptable. 
Predetermined cutoff scores shall not be employed.
    (vi) Technical evaluation report. A technical evaluation report 
shall be prepared and furnished to the contracting officer by the 
chairperson and maintained as a permanent record in the contract file. 
The report must reflect the ranking of the proposals and identify each 
proposal as acceptable or unacceptable. The report must also include a 
narrative evaluation specifying the strengths and weaknesses of each 
proposal, a copy of each signed rating sheet, and any reservations, 
qualifications, or areas to be addressed that might bear upon the 
selection of sources for negotiation and award. Concrete technical 
reasons supporting a determination of unacceptability with regard to any 
proposal must be included. The report should also include specific 
points and questions which are to be raised in discussions or 
negotiations.



Sec. 315.306  Exchanges with offerors after receipt of proposals.

    (d) Exchanges with offerors after establishment of the competitive 
range. The contracting officer and project officer should discuss the 
uncertainties and/or deficiencies that are included in the technical 
evaluation report for each proposal in the competitive range. Technical 
questions should be developed by the project officer and/or the 
technical evaluation panel and should be included in the technical 
evaluation report. The management, past performance and cost or price 
questions should be prepared by the contracting officer with assistance 
from the project officer and/or panel as required. The method of 
requesting offerors in the competitive range to submit the additional 
information will vary depending on the complexity of the questions, the 
extent

[[Page 37]]

of additional information requested, the time needed to analyze the 
responses, and the time frame for making the award. However, to the 
extent practicable, all questions and answers should be in writing. Each 
offeror in the competitive range shall be given an equitable period of 
time for preparation of responses to questions to the extent 
practicable. The questions should be developed so as to disclose the 
ambiguities, uncertainties, and deficiencies of the offeror.



Sec. 315.307  Proposal revisions.

    (b) Final proposal revisions are subject to a final evaluation of 
price or cost and other salient factors by the contracting officer and 
project officer with assistance from a cost/price analyst, and an 
evaluation of technical factors by the technical evaluation panel, as 
necessary. Proposals may be technically rescored and reranked by the 
technical evaluation panel and a technical evaluation report prepared. 
To the extent practicable, the evaluation shall be performed by the same 
evaluators who reviewed the original proposals. A final evaluation of 
past performance will be made by the contracting officer and project 
officer. The technical evaluation panel may be involved in the final 
evaluation of past performance if the panel is comprised solely of 
Government personnel.



Sec. 315.370  Finalization of details with the selected source.

    (a) After selection of the successful proposal, finalization of 
details with the selected offeror may be conducted if deemed necessary. 
However, no factor which could have any effect on the selection process 
may be introduced after the common cutoff date for receipt of final 
proposal revisions. The finalization process shall not in any way 
prejudice the competitive interest or rights of the unsuccessful 
offerors. Finalization of details with the selected offeror shall be 
restricted to definitizing the final agreement on terms and conditions, 
assuming none of these factors were involved in the selection process.
    (b) Caution must be exercised by the contracting officer to insure 
that the finalization process is not used to change the requirements 
contained in the solicitation, nor to make any other changes which would 
impact on the source selection decision. Whenever a material change 
occurs in the requirements, the competition must be reopened and all 
offerors submitting final proposal revisions must be given an 
opportunity to resubmit proposals based on the revised requirements. 
Whenever there is a question as to whether a change is material, the 
contracting officer should obtain the advice of technical personnel and 
legal counsel before reopening the competition. Significant changes in 
the offeror's cost proposal may also necessitate a reopening of 
competition if the changes alter the factors involved in the original 
selection process.
    (c) Should finalization details beyond those specified in paragraph 
(a) of this section be required for any reason, discussions must be 
reopened with all offerors submitting final proposal revisions.
    (d) Upon finalization of details, the contracting officer should 
obtain a confirmation letter from the successful offeror which includes 
any revisions to the technical proposal, the agreed to price or cost, 
and, as applicable, a certificate of current cost or pricing data.



Sec. 315.371  Contract preparation and award.

    (a) The contracting officer must perform the following actions after 
finalization details have been completed:
    (1) Prepare the negotiation memorandum in accordance with 315.372;
    (2) Prepare the contract containing all agreed to terms and 
conditions and clauses required by law or regulation;
    (3) Include in the contract file the pertinent documents referenced 
in FAR 4.803; and
    (4) Obtain the appropriate approval of the proposed contract 
award(s) in accordance with subpart 304.71 and contracting activity 
procedures.
    (b) After receiving the required approvals, the contract should be 
transmitted to the prospective contractor for signature. The prospective 
contractor must be informed that the contract is not effective until 
accepted by the contracting officer.

[[Page 38]]

    (c) The contract shall not be issued until the finance office 
certifies that the funds are available for obligation.



Sec. 315.372  Preparation of negotiation memorandum.

    The negotiation memorandum or summary of negotiations is a complete 
record of all actions leading to award of a contract and is prepared by 
the contract negotiator to support the source selection decision 
discussed in FAR 15.308. It should be in sufficient detail to explain 
and support the rationale, judgments, and authorities upon which all 
actions were predicated. The memorandum will document the negotiation 
process and reflect the negotiator's actions, skills, and judgments in 
concluding a satisfactory agreement for the Government. Negotiation 
memorandums shall contain discussion of the following or a statement of 
nonapplicability; however, information already contained in the contract 
file need not be reiterated. A reference to the document which contains 
the required information is acceptable.
    (a) Description of articles and services and period of performance. 
A description of articles and services, quantity, unit price, total 
contract amount, and period of contract performance should be set forth 
( if Supplemental Agreement--show previous contract amount as revised, 
as well as information with respect to the period of performance).
    (b) Acquisition planning. Summarize or reference any acquisition 
planning activities that have taken place.
    (c) Synopsis of acquisition. A statement as to whether the 
acquisition has or has not been publicized in accordance with FAR 
Subpart 5.2. A brief statement of explanation should be included with 
reference to the specific basis for exemption under the FAR, if 
applicable.
    (d) Contract type. Provide sufficient detail to support the type of 
contractual instrument recommended for the acquisition. If the contract 
is a cost-sharing type, explain the essential cost-sharing features.
    (e) Extent of competition. The extent to which full and open 
competition was solicited and obtained must be discussed. The discussion 
shall include the date of solicitation, sources solicited, and 
solicitation results. If a late proposal was received, discuss whether 
or not the late proposal was evaluated and the rationale for the 
decision.
    (f) Technical evaluation. Summarize or reference the results 
presented in the technical evaluation report.
    (g) Business evaluation. Summarize or reference results presented in 
the business report.
    (h) Past performance. Summarize or reference results of past 
performance evaluation and reference checks.
    (i) Competitive range (if applicable). Describe how the competitive 
range was determined and state the offerors who were included in the 
competitive range and the ones who were not.
    (j) Cost breakdown and analysis. Include a complete cost breakdown 
together with the negotiator's analysis of the estimated cost by 
individual cost elements. The negotiator's analysis should contain 
information such as:
    (1) A comparison of cost factors proposed in the instant case with 
actual factors used in earlier contracts, using the same cost centers of 
the same supplier or cost centers of other sources having recent 
contracts for the same or similar item.
    (2) Any pertinent Government-conducted audit of the proposed 
contractor's record of any pertinent cost advisory report.
    (3) Any pertinent technical evaluation inputs as to necessity, 
allocability and reasonableness of labor, material and other direct 
expenses.
    (4) Any other pertinent information to fully support the basis for 
and rationale of the cost analysis.
    (5) If the contract is an incentive type, discuss all elements of 
profit and fee structure.
    (6) A justification of the reasonableness of the proposed 
contractor's estimated profit or fixed fee, considering the requirements 
of FAR 15.404-4 and HHSAR 315.404-4.
    (k) Cost realism. Describe the cost realism analysis performed on 
proposals.
    (l) Government-furnished property and Government-provided 
facilities. With respect to Government-furnished or Government-provided 
facilities, equipment, tooling, or other property, include the 
following:

[[Page 39]]

    (1) Where no property is to be provided, a statement to that effect.
    (2) Where property is to be provided, a full description, the 
estimated dollar value, the basis of price comparison with competitors, 
and the basis of rental charge, if rental is involved.
    (3) Where the furnishing of any property or the extent has not been 
determined and is left open for future resolution, a detailed 
explanation.
    (m) Negotiations. Include a statement as to the date and place 
negotiations were conducted, and identify members of both the Government 
and contractor negotiating teams by area of responsibility. Include 
negotiation details relative to the statement of work, terms and 
conditions, and special provisions. The results of cost or price 
negotiations must include the information required by FAR 31.109 and 
15.406-3. In addition, if cost or pricing data was required to be 
submitted, the negotiation record must also contain the extent to which 
the contracting officer relied upon the factual cost or pricing data 
submitted and used in negotiating the cost or price.
    (n) Other considerations. Include coverage of areas such as:
    (1) Financial data with respect to a contractor's capacity and 
stability.
    (2) Determination of contractor responsibility.
    (3) Details as to why the method of payment, such as progress 
payment, advance payment, etc., is necessary. Also cite any required D & 
F's.
    (4) Information with respect to obtaining of a certificate of 
current cost or pricing data.
    (5) Other required special approvals.
    (6) If the contract represents an extension of previous work, the 
status of funds and performance under the prior contract(s) should be 
reflected. Also, a determination should be made that the Government has 
obtained enough actual or potential value from the work previously 
performed to warrant continuation with the same contractor. (Project 
officer should furnish the necessary information.)
    (7) If the contract was awarded by full and open competition, state 
where the unsuccessful offerors' proposals are filed.
    (8) State that equal opportunity provisions of the proposed contract 
have been explained to the contractor, and it is aware of its 
responsibilities. Also state whether or not a clearance is required.
    (9) If the contract is for services, a statement must be made, in 
accordance with FAR 37.103, that the services to be acquired are 
nonpersonal in nature.
    (o) Terms and conditions. Identify the general and special clauses 
and conditions that are contained in the contract, such as option 
arrangements, incremental funding, anticipatory costs, deviations from 
standard clauses, etc. The basis and rationale for inclusion of any 
special terms and conditions must be stated and, where applicable, the 
document which granted approval for its use identified.
    (p) Recommendation. A brief statement setting forth the 
recommendations for award.
    (q) Signature. The memorandum must be signed by the contract 
negotiator who prepared the memorandum.

                     Subpart 315.4_Contract Pricing



Sec. 315.404  Proposal analysis.



Sec. 315.404-2  Information to support proposal analysis.

    (a)(2) When some or all information sufficient to determine the 
reasonableness of the proposed cost or price is already available or can 
be obtained by phone from the cognizant audit agency, contracting 
officers may request less-than-complete field pricing support 
(specifying in the request the information needed) or may waive in 
writing the requirement for audit and field pricing support by 
documenting the file to indicate what information is to be used instead 
of the audit report and the field pricing report.
    (3) When initiating audit and field pricing support, the contracting 
officer shall do so by sending a request to the cognizant administrative 
contracting officer (ACO), with an information copy to the cognizant 
audit office. When field pricing support is not available, the 
contracting officer shall initiate an audit by sending, in accordance 
with agency procedures, two (2) copies of the request to the OIG Office

[[Page 40]]

of Audits' Regional Audit Director. In both cases, the contracting 
officer shall, in the request:
    (i) Prescribe the extent of the support needed;
    (ii) State the specific areas for which input is required;
    (iii) Include the information necessary to perform the review (such 
as the offeror's proposal and the applicable portions of the 
solicitation, particularly those describing requirements and delivery 
schedules);
    (iv) Provide the complete address of the location of the offeror's 
financial records that support the proposal;
    (v) Identify the office having audit responsibility if other than 
the HHS Regional Audit Office; and
    (vi) Specify a due date for receipt of a verbal report to be 
followed by a written audit report. (If the time available is not 
adequate to permit satisfactory coverage of the proposal, the auditor 
shall so advise the contracting officer and indicate the additional time 
needed.) One copy of the audit request letter that was submitted to the 
Regional Audit Director and a complete copy of the contract price 
proposal shall be submitted to OIG/OA/DAC. Whenever, an audit review has 
been conducted by the Office of Audits, two (2) copies of the memorandum 
of negotiation shall be forwarded to OIG/OA/DAC by the contracting 
officer.



Sec. 315.404-4  Profit.

    (b) Policy. (1) The structured approach for determining profit or 
fee (hereafter referred to as profit) provides contracting officers with 
a technique that will ensure consideration of the relative value of the 
appropriate profit factors described in paragraph (d) of this section in 
the establishment of a profit objective for the conduct of negotiations. 
The contracting officer's analysis of these profit factors is based on 
information available to him/her prior to negotiations. The information 
is furnished in proposals, audit data, assessment reports, preaward 
surveys and the like. The structured approach also provides a basis for 
documentation of this objective, including an explanation of any 
significant departure from this objective in reaching an agreement. The 
extent of documentation should be directly related to the dollar value 
and complexity of the proposed acquisition. Additionally, the 
negotiation process does not require agreement on either estimated cost 
elements or profit elements. The profit objective is a part of an 
overall negotiation objective which, as a going-in objective, bears a 
distinct relationship to the cost objective and any proposed sharing 
arrangement. Since profit is merely one of several interrelated 
variables, the Government negotiator generally should not complete the 
profit negotiation without simultaneously agreeing on the other 
variables. Specific agreement on the exact weights or values of the 
individual profit factors is not required and should not be attempted.
    (ii) The profit-analysis factors set forth at FAR 15.404-4(d) shall 
be used for establishing profit objectives under the following listed 
circumstances. Generally, it is expected that this method will be 
supported in a manner similar to that used in the structured approach 
(profit factor breakdown and documentation of the profit objective); 
however, factors within FAR 15.404-4(d) considered inapplicable to the 
acquisition will be excluded from the profit objective.
    (A) Contracts not expected to exceed $100,000;
    (B) Architect-engineer contracts;
    (C) Management contracts for operations and/or maintenance of 
Government facilities;
    (D) Construction contracts;
    (E) Contracts primarily requiring delivery of material supplies by 
subcontractors;
    (F) Termination settlements; and
    (G) Cost-plus-award-fee contracts (However, contracting officers may 
find it advantageous to perform a structured profit analysis as an aid 
in arriving at an appropriate fee arrangement). Other exceptions may be 
made in the negotiation of contracts having unusual pricing situations, 
but shall be justified in writing by the contracting officer in 
situations where the structured approach is determined to be unsuitable.
    (c) Contracting officer responsibilities. A profit objective is that 
part of the estimated contract price objective or

[[Page 41]]

value which, in the judgment of the contracting officer, constitutes an 
appropriate amount of profit for the acquisition being considered. This 
objective should realistically reflect the total overall task to be 
performed and the requirements placed on the contractor. Development of 
a profit objective should not begin until a thorough review of proposed 
contract work has been made; a review of all available knowledge 
regarding the contractor pursuant to FAR subpart 9.1, including audit 
data, preaward survey reports and financial statements, as appropriate, 
has been conducted; and an analysis of the contractor's cost estimate 
and comparison with the Government's estimate or projection of cost has 
been made.
    (d) Profit--analysis factors (1) Common factors. The following 
factors shall be considered in all cases in which profit is to be 
negotiated. The weight ranges listed after each factor shall be used in 
all instances where the structured approach is used.

------------------------------------------------------------------------
             Profit factors                 Weight ranges (in percent)
------------------------------------------------------------------------
Contractor effort:
  Material acquisition.................  1 to 5.
  Direct labor.........................  4 to 15.
  Overhead.............................  4 to 9.
  General management (G&A).............  4 to 8.
  Other costs..........................  1 to 5.
Other factors:
  Cost risk............................  0 to 7.
  Investment...........................  -2 to +2.
  Performance..........................  -1 to +1.
  Socioeconomic programs...............  -.5 to +.5.
  Special situations...................
------------------------------------------------------------------------

    (i) Under the structured approach, the contracting officer shall 
first measure ``Contractor Effort'' by the assignment of a profit 
percentage within the designated weight ranges to each element of 
contract cost recognized by the contracting officer. The amount 
calculated for the cost of money for facilities capital is not to be 
included for the computation of profit as part of the cost base. The 
suggested categories under ``Contractor Effort'' are for reference 
purposes only. Often individual proposals will be in a different format, 
but since these categories are broad and basic, they provide sufficient 
guidance to evaluate all other items of cost.
    (ii) After computing a total dollar profit for ``Contractor 
Effort,'' the contracting officer shall then calculate the specific 
profit dollars assigned for cost risk, investment, performance, 
socioeconomic programs, and special situations. This is accomplished by 
multiplying the total Government Cost Objective, exclusive of any cost 
of money for facilities capital, by the specific weight assigned to the 
elements within the ``Other Factors'' category. Form HHS-674, Structured 
Approach Profit/Fee Objective, should be used, as appropriate, to 
facilitate the calculation of this profit objective. Form HHS-674 is 
illustrated in 353.370-674.
    (iii) In making a judgment of the value of each factor, the 
contracting officer should be governed by the definition, description, 
and purpose of the factors together with considerations for evaluating 
them.
    (iv) The structured approach was designed for arriving at profit 
objectives for other than nonprofit organizations. However, if 
appropriate adjustments are made to reflect differences between profit 
and nonprofit organizations, the structured approach can be used as a 
basis for arriving at profit objectives for nonprofit organizations. 
Therefore, the structured approach, as modified in paragraph 
(d)(1)(iv)(B) of this section, shall be used to establish profit 
objectives for nonprofit organizations.
    (A) For purposes of this section, nonprofit organizations are 
defined as those business entities organized and operated exclusively 
for charitable, scientific, or educational purposes, no part of the net 
earnings of which inure to the benefit of any private shareholder or 
individual, and which are exempt from Federal income taxation under 
Section 501 of the Internal Revenue Code.
    (B) For contracts with nonprofit organizations where profit is 
involved, an adjustment of up to 3 percentage points will be subtracted 
from the total profit objective percentage. In developing this 
adjustment, it will be necessary to consider the following factors;
    (1) Tax position benefits;
    (2) Granting of financing through advance payments; and
    (3) Other pertinent factors which may work to either the advantage 
or

[[Page 42]]

disadvantage of the contractor in its position as a nonprofit 
organization.
    (2) Contractor effort. Contractor effort is a measure of how much 
the contractor is expected to contribute to the overall effort necessary 
to meet the contract performance requirement in an efficient manner. 
This factor, which is apart from the contractor's responsibility for 
contract performance, takes into account what resources are necessary 
and what the contractor must do to accomplish a conversion of ideas and 
material into the final service or product called for in the contract. 
This is a recognition that within a given performance output, or within 
a given sales dollar figure, necessary efforts on the part of individual 
contractors can vary widely in both value and quantity, and that the 
profit objective should reflect the extent and nature of the 
contractor's contribution to total performance. A major consideration, 
particularly in connection with experimental, developmental, or research 
work, is the difficulty or complexity of the work to be performed, and 
the unusual demands of the contract, such as whether the project 
involves a new approach unrelated to existing technology and/or 
equipment or only refinements to these items. The evaluation of this 
factor requires an analysis of the cost content of the proposed contract 
as follows:
    (i) Material acquisition. (Subcontracted items, purchased parts, and 
other material.) Analysis of these cost items shall include an 
evaluation of the managerial and technical effort necessary to obtain 
the required subcontracted items, purchased parts, material or services. 
The contracting officer shall determine whether the contractor will 
obtain the items or services by routine order from readily available 
sources or by detailed subcontracts for which the prime contractor will 
be required to develop complex specifications. Consideration shall also 
be given to the managerial and technical efforts necessary for the prime 
contractor to select subcontractors and to perform subcontract 
administration functions. In application of this criterion, it should be 
recognized that the contribution of the prime contractor to its 
purchasing program may be substantial. Normally, the lowest unadjusted 
weight for direct material is 2 percent. A weighting of less than 2 
percent would be appropriate only in unusual circumstances when there is 
a minimal contribution by the contractor.
    (ii) Direct labor. (Professional, service, manufacturing and other 
labor). Analysis of the various labor categories of the cost content of 
the contract should include evaluation of the comparative quality and 
quantity of professional and semiprofessional talents, manufacturing and 
service skills, and experience to be employed. In evaluating 
professional and semiprofessional labor for the purpose of assigning 
profit dollars, consideration should be given to the amount of notable 
scientific talent or unusual or scarce talent needed in contrast to 
nonprofessional effort. The assessment should consider the contribution 
this talent will provide toward the achievement of contract objectives. 
Since nonprofessional labor is relatively plentiful and rather easily 
obtained by the contractor and is less critical to the successful 
performance of contract objectives, it cannot be weighted nearly as high 
as professional or semiprofessional labor. Service contract labor should 
be evaluated in a like manner by assigning higher weights to engineering 
or professional type skills required for contract performance. 
Similarly, the variety of manufacturing and other categories of labor 
skills required and the contractor's manpower resources for meeting 
these requirements should be considered. For purposes of evaluation, 
categories of labor (i.e., quality control, receiving and inspection, 
etc.) which do not fall within the definition for professional, service 
or manufacturing labor may be categorized as appropriate. However, the 
same evaluation considerations as outlined in this paragraph will be 
applied.
    (iii) Overhead and general management (G&A). (A) Analysis of these 
overhead items of cost should include the evaluation of the makeup of 
these expenses and how much they contribute to contract performance. To 
the extent practicable, analysis should include a determination of the 
amount of labor

[[Page 43]]

within these overhead pools and how this labor should be treated if it 
were considered as direct labor under the contract. The allocable labor 
elements should be given the same profit considerations that they would 
receive if they were treated as direct labor. The other elements of 
these overhead pools should be evaluated to determine whether they are 
routine expenses, such as utilities and maintenance, and hence given 
lesser profit consideration, or whether they are significant 
contributing elements. The composite of the individual determinations in 
relation to the elements of the overhead pools will be the profit 
consideration given the pools as a whole. The procedure for assigning 
relative values to these overhead expenses differs from the method used 
in assigning values of the direct labor. The upper and lower limits 
assignable to the direct labor are absolute. In the case of overhead 
expenses, individual expenses may be assigned values outside the range 
as long as the composite ratio is within the range.
    (B) It is not necessary that the contractor's accounting system 
break down overhead expenses within the classifications of research 
overhead, other overhead pools, and general administrative expenses, 
unless dictated otherwise by Cost Accounting Standards (CAS). The 
contractor whose accounting system reflects only one overhead rate on 
all direct labor need not change its system (if CAS exempt) to 
correspond with these classifications. The contracting officer, in an 
evaluation of such a contractor's overhead rate, could break out the 
applicable sections of the composite rate which could be classified as 
research overhead, other overhead pools, and general and administrative 
expenses, and follow the appropriate evaluation technique.
    (C) Management problems surface in various degrees and the 
management expertise exercised to solve them should be considered as an 
element of profit. For example, a contract for a new program for 
research or an item which is on the cutting edge of the state of the art 
will cause more problems and require more managerial time and abilities 
of a higher order than a follow-on contract. If new contracts create 
more problems and require a higher profit weight, follow-ons should be 
adjusted downward because many of the problems should have been solved. 
In any event, an evaluation should be made of the underlying managerial 
effort involved on a case-by-case basis.
    (D) It may not be necessary for the contracting officer to make a 
separate profit evaluation of overhead expenses in connection with each 
acquisition action for substantially the same project with the same 
contractor. Where an analysis of the profit weight to be assigned to the 
overhead pool has been made, that weight assigned may be used for future 
acquisitions with the same contractor until there is a change in the 
cost composition of the overhead pool or the contract circumstances, or 
the factors discussed in paragraph (d)(2)(iii)(C) of this section are 
involved.
    (iv) Other costs. Analysis of this factor should include all other 
direct costs associated with contractor performance (e.g., travel and 
relocation, direct support, and consultants). Analysis of these items of 
cost should include, the significance of the cost of contract 
performance, nature of the cost, and how much they contribute to 
contract performance. Normally, travel costs require minimal 
administrative effort by the contractor and, therefore, usually receive 
a weight no greater than 1%. Also, the contractor may designate 
individuals as ``consultants'' but in reality these individuals may be 
obtained by the contractor to supplement its workforce in the 
performance of routine duties required by contract. These costs would 
normally receive a minimum weight. However, there will be instances when 
the contractor may be required to locate and obtain the services of 
consultants having expertise in fields such as medicine or human 
services. In these instances, the contractor will be required to expend 
greater managerial and technical effort to obtain these services and, 
consequently, the costs should receive a much greater weight.
    (3) Other factors (i) Contract cost risk. The contract type employed 
basically determines the degree of cost risk assumed by the contractor. 
For example,

[[Page 44]]

where a portion of the risk has been shifted to the Government through 
cost-reimbursement provisions, unusual contingency provisions, or other 
risk-reducing measures, the amount of profit should be less than where 
the contractor assumes all the risk.
    (A) In developing the prenegotiation profit objective, the 
contracting officer will need to consider the type of contract 
anticipated to be negotiated and the contractor risk associated 
therewith when selecting the position in the weight range for profit 
that is appropriate for the risk to be borne by the contractor. This 
factor should be one of the most important in arriving at prenegotiation 
profit objective. Evaluation of this risk requires a determination of 
the degree of cost responsibility the contractor assumes; the 
reliability of the cost estimates in relation to the task assumed; and 
the complexity of the task assumed by the contractor. This factor is 
specifically limited to the risk of contract costs. Thus, risks on the 
part of the contractor such as reputation, losing a commercial market, 
risk of losing potential profits in other fields, or any risk which 
falls on the contracting office, such as the risk of not acquiring a 
satisfactory report, are not within the scope of this factor.
    (B) The first and basic determination of the degree of cost 
responsibility assumed by the contractor is related to the sharing of 
total risk of contract cost by the Government and the contractor through 
the selection of contract type. The extremes are a cost-plus-a-fixed-fee 
contract requiring the contractor to use its best efforts to perform a 
task and a firm fixed-price contract for a service or a complex item. A 
cost-plus-a-fixed-fee contract would reflect a minimum assumption of 
cost responsibility, whereas a firm-fixed-price contract would reflect a 
complete assumption of cost responsibility. Where proper contract 
selection has been made, the regard for risk by contract type would 
usually fall into the following percentage ranges:

------------------------------------------------------------------------
                                                                 Percent
------------------------------------------------------------------------
Cost-reimbursement type contracts.............................       0-3
Fixed-price type contracts....................................       2-7
------------------------------------------------------------------------

    (C) The second determination is that of the reliability of the cost 
estimates. Sound price negotiation requires well-defined contract 
objectives and reliable cost estimates. Prior experience assists the 
contractor in preparing reliable cost estimates on new acquisitions for 
similar related efforts. An excessive cost estimate reduces the 
possibility that the cost of performance will exceed the contract price, 
thereby reducing the contractor's assumption of contract cost risk.
    (D) The third determination is that of the difficulty of the 
contractor's task. The contractor's task can be difficult or easy, 
regardless of the type of contract.
    (E) Contractors are likely to assume greater cost risk only if 
contracting officers objectively analyze the risk incident to proposed 
contracts and are willing to compensate contractors for it. Generally, a 
cost-plus-fixed fee contract will not justify a reward for risk in 
excess of 0.5 percent, nor will a firm fixed-price contract justify a 
reward of less than the minimum in the structured approach. Where proper 
contract-type selection has been made, the reward for risk, by contract 
type, will usually fall into the following percentage ranges:
    (1) Type of contract and percentage ranges for profit objectives 
developed by using the structured approach for research and development 
and manufacturing contracts:

------------------------------------------------------------------------
                                                       Percent
------------------------------------------------------------------------
Cost-Plus-fixed fee.......................  0 to 0.5
Cost-plus-incentive fee:
  With cost incentive only................  1 to 2
  With multiple incentives................  1.5 to 3
Fixed-price-incentive:
  With cost incentive only................  2 to 4
  With multiple incentives................  3 to 5
  Prospective price redetermination.......  3 to 5
  Firm fixed-price........................  5 to 7
------------------------------------------------------------------------

    (2) Type of contract and percentage ranges for profit objectives 
developed by using the structured approach for service contracts:

------------------------------------------------------------------------
                                                       Percent
------------------------------------------------------------------------
Cost-plus-fixed-fee.......................  0 to 0.5
Cost-plus-incentive fee...................  1 to 2
Fixed-price incentive.....................  2 to 3
Firm fixed-price..........................  3 to 4
------------------------------------------------------------------------


[[Page 45]]

    (F) These ranges may not be appropriate for all acquisitions. For 
instance, a fixed-price-incentive contract that is closely priced with a 
low ceiling price and high incentive share may be tantamount to a firm 
fixed-price contract. In this situation, the contracting officer may 
determine that a basis exists for high confidence in the reasonableness 
of the estimate and that little opportunity exists for cost reduction 
without extraordinary efforts. On the other hand, a contract with a high 
ceiling and low incentive formula can be considered to contain cost-plus 
incentive-fee contract features. In this situation, the contracting 
officer may determine that the Government is retaining much of the 
contract cost responsibility and that the risk assumed by the contractor 
is minimal. Similarly, if a cost-plus-incentive-fee contract includes an 
unlimited downward (negative) fee adjustment on cost control, it could 
be comparable to a fixed-price-incentive contract. In such a pricing 
environment, the contracting officer may determine that the Government 
has transferred a greater amount of cost responsibility to the 
contractor than is typical under a normal cost-plus-incentive-fee 
contract.
    (G) The contractor's subcontracting program may have a significant 
impact on the contractor's acceptance or risk under a contract form. It 
could cause risk to increase or decrease in terms of both cost and 
performance. This consideration should be a part of the contracting 
officer's overall evaluation in selecting a factor to apply for cost 
risk. It may be determined, for instance, that the prime contractor has 
effectively transferred real cost risk to a subcontractor and the 
contract cost risk evaluation may, as a result, be below the range which 
would otherwise apply for the contract type being proposed. The contract 
cost risk evaluation should not be lowered, however, merely on the basis 
that a substantial portion of the contract costs represents subcontracts 
without any substantial transfer of contractor's risk.
    (H) In making a contract cost risk evaluation in an acquisition 
action that involves definitization of a letter contract, unpriced 
change orders, and unpriced orders under basic ordering agreements, 
consideration should be given to the effect on total contract cost risk 
as a result of having partial performance before definitization. Under 
some circumstances it may be reasoned that the total amount of cost risk 
has been effectively reduced. Under other circumstances it may be 
apparent that the contractor's cost risk remained substantially 
unchanged. To be equitable, the determination of profit weight for 
application to the total of all recognized costs, both those incurred 
and those yet to be expended, must be made with consideration to all 
attendant circumstances--not just the portion of costs incurred or 
percentage of work completed prior to definitization.
    (I) Time and material and labor hour contracts will be considered to 
be cost-plus-a-fixed-fee contracts for the purpose of establishing 
profit weights unless otherwise exempt under paragraph (b)(1)(ii) of 
this section in the evaluation of the contractor's assumption of 
contract cost risk.
    (ii) Investment. HHS encourages its contractors to perform their 
contracts with the minimum of financial, facilities, or other assistance 
from the Government. As such, it is the purpose of this factor to 
encourage the contractor to acquire and use its own resources to the 
maximum extent possible. The evaluation of this factor should include an 
analysis of the following:
    (A) Facilities. (Including equipment). To evaluate how this factor 
contributes to the profit objective requires knowledge of the level of 
facilities utilization needed for contract performance, the source and 
financing of the required facilities, and the overall cost effectiveness 
of the facilities offered. Contractors who furnish their own facilities 
which significantly contribute to lower total contract costs should be 
provided with additional profit. On the other hand, contractors who rely 
on the Government to provide or finance needed facilities should receive 
a corresponding reduction in profit. Cases between these examples should 
be evaluated on their merits with either positive or negative 
adjustments, as appropriate, in profit being made. However, where a 
highly facilitized contractor is to perform a contract which does not

[[Page 46]]

benefit from this facilitization or where a contractor's use of its 
facilities has a minimum cost impact on the contract, profit need not be 
adjusted. When applicable, the prospective contractor's computation of 
facilities capital cost of money for pricing purposed under CAS 414 can 
help the contracting officer identify the level of facilities investment 
to be employed in contract performance.
    (B) Payments. In analyzing this factor, consideration should be 
given to the frequency of payments by the Government to the contractor. 
The key to this weighting is to give proper consideration to the impact 
the contract will have on the contractor's cash flow. Generally, 
negative consideration should be given for advance payments and payments 
more frequent than monthly with maximum reduction being given as the 
contractor's working capital approaches zero. Positive consideration 
should be given for payments less frequent than monthly with additional 
consideration given for a capital turn-over rate on the contract which 
is less than the contractor's or the industry's normal capital turn-over 
rate.
    (iii) Performance. (Cost-control and other past accomplishments.) 
The contractor's past performance should be evaluated in such areas as 
quality of service or product, meeting performance schedules, efficiency 
in cost control (including need for and reasonableness of cost 
incurred), accuracy and reliability of previous cost estimates, degree 
of cooperation by the contractor (both business and technical), timely 
processing of changes and compliance with other contractual provisions, 
and management of subcontract programs. Where a contractor has 
consistently achieved excellent results in these areas in comparison 
with other contractors in similar circumstances, this performance merits 
a proportionately greater opportunity for profit. Conversely, a poor 
record in this regard should be reflected in determining what 
constitutes a fair and reasonable profit.
    (iv) Federal socioeconomic programs. This factor, which may apply to 
special circumstances or particular acquisitions, relates to the extent 
of a contractor's successful participation in Government sponsored 
programs such as small business, small disadvantaged business, women-
owned small business, and energy conservation efforts. The contractor's 
policies and procedures which energetically support Government 
socioeconomic programs and achieve successful results should be given 
positive considerations. Conversely, failure or unwillingness on the 
part of the contractor to support Government socioeconomic programs 
should be viewed as evidence of poor performance for the purpose of 
establishing a profit objective.
    (v) Special situations (A) Inventive and developmental 
contributions. The extent and nature of contractor-initiated and 
financed independent development should be considered in developing the 
profit objective, provided that the contracting officer has made a 
determination that the effort will benefit the contract. The importance 
of the development in furthering health and human services purposes, the 
demonstrable initiative in determining the need and application of the 
development, the extent of the contractor's cost risk, and whether the 
development cost was recovered directly or indirectly from Government 
sources should be weighed.
    (B) Unusual pricing agreements. Occasionally, unusual contract 
pricing arrangements are made with the contractor wherein it agrees to 
cost ceilings, e.g., a ceiling on overhead rates for conditions other 
than those discussed at FAR 42.707. In these circumstances, the 
contractor should receive favorable consideration in developing the 
profit objective.
    (C) Negative factors. Special situations need not be limited to 
those which only increase profit levels. A negative consideration may be 
appropriate when the contractor is expected to obtain spin-off-benefits 
as a direct result of the contract (e.g., products or services with 
commercial application).
    (4) Facilities capital cost of money. When facilities capital cost 
of money (cost of capital committed to facilities) is included as an 
item of cost in the contractor's proposal, a reduction in the profit 
objective shall be made in an

[[Page 47]]

amount equal to the amount of facilities capital cost of money allowed 
in accordance with the Facilities Capital Cost-of Money Cost Principal. 
If the contractor does not propose this cost, a provision must be 
inserted in the contract that facilities capital cost of money is not an 
allowable cost.

                   Subpart 315.6_Unsolicited Proposals



Sec. 315.605  Content of unsolicited proposals.

    (d) Certification by offeror--To ensure against contacts between 
Department employees and prospective offerors which would exceed the 
limits of advance guidance set forth in FAR 15.604 resulting in an 
unfair advantage to an offeror, the contracting officer shall ensure 
that the following certification is furnished to the prospective offeror 
and the executed certification is included as part of the resultant 
unsolicited proposal:

                          Unsolicited Proposal

                        Certification by Offeror

    This is to certify, to the best of my knowledge and belief, that:
    (a) This proposal has not been prepared under Government 
supervision.
    (b) The methods and approaches stated in the proposal were developed 
by this offeror.
    (c) Any contact with employees of the Department of Health and Human 
Services has been within the limits of appropriate advance guidance set 
forth in FAR 15.604.
    (d) No prior commitments were received from departmental employees 
regarding acceptance of this proposal.

Date:___________________________________________________________________

Organization:___________________________________________________________

Name:___________________________________________________________________

Title:__________________________________________________________________

(This certification shall be signed by a responsible official of the 
proposing organization or a person authorized to contractually obligate 
the organization.)



Sec. 315.606  Agency procedures.

    (a) The HCA is responsible for establishing procedures to comply 
with FAR 15.606(a).
    (b) The HCA or his/her designee shall be the point of contract for 
coordinating the receipt and handling of unsolicited proposals.



Sec. 315.606-1  Receipt and initial review.

    (d) An unsolicited proposal shall not be refused consideration 
merely because it was initially submitted as a grant application. 
However, contracts shall not be awarded on the basis of unsolicited 
proposals which have been rejected for grant support on the grounds that 
they lack scientific merit.



Sec. 315.609  Limited use of data.

    The legend, Use and Disclosure of Data, prescribed in FAR 15.609(a) 
is to be used by the offeror to restrict the use of data for evaluation 
purposes only. However, data contained within the unsolicited proposal 
may have to be disclosed as a result of a request submitted pursuant to 
the Freedom of Information Act. Because of this possibility, the 
following notice shall be furnished to all prospective offerors of 
unsolicited proposals whenever the legend is provided in accordance with 
FAR 15.604(a)(7):

    The Government will attempt to comply with the ``Use and Disclosure 
of Data'' legend.
    However, the Government may not be able to withhold a record (data, 
document, etc.) nor deny access to a record requested by an individual 
(the public) when an obligation is imposed on the Government under the 
Freedom of Information Act, 5 U.S.C. 552, as amended. The Government 
determination to withhold or disclose a record will be based upon the 
particular circumstances involving the record in question and whether 
the record may be exempted from disclosure under the Freedom of 
Information Act. Records which the offeror considers to be trade secrets 
and commercial or financial information and privileged or confidential 
must be identified by the offeror as indicated in the referenced legend.

                       PART 316_TYPES OF CONTRACTS

               Subpart 316.3_Cost-Reimbursement Contracts

Sec.

Sec. 316.307  Contract clauses.

   Subpart 316.6_Time-and-Materials, Labor-Hour, and Letter Contracts


Sec. 316.603  Letter contracts.

Sec. 316.603-3  Limitations.

Sec. 316.603-70  Information to be furnished when requesting authority 
          to issue a letter contract.

[[Page 48]]


Sec. 316.603-71  Approval for modifications to letter contracts.

                        Subpart 316.7_Agreements


Sec. 316.770  Unauthorized types of agreements.

Sec. 316.770-1  Letter of intent.

Sec. 316.770-2  Memorandums of understanding.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4243, Jan. 17, 2001, unless otherwise noted.

               Subpart 316.3_Cost-Reimbursement Contracts



Sec. 316.307  Contract clauses.

    (a) If the contract is with a hospital (profit or nonprofit) for 
research and development, modify the ``Allowable Cost and Payment'' 
clause at FAR 52.216-7 by deleting from paragraph (a) the words 
``Subpart 31.2 of the Federal Acquisition Regulation (FAR)'' and 
substituting ``45 CFR Part 74 Appendix E.''
    (j) The contracting officer shall insert the clause at 352.216-72, 
Additional Cost Principles, in all solicitations and resultant cost-
reimbursement contracts.

   Subpart 316.6_Time-and-Materials, Labor-Hour, and Letter Contracts



Sec. 316.603  Letter contracts.



Sec. 316.603-3  Limitations.

    An official one level above the contracting officer shall execute 
the prescribed written statement.



Sec. 316.603-70  Information to be furnished when requesting authority 
          to issue a letter contract.

    The following information should be included by the contracting 
officer in any memorandum requesting approval to issue a letter 
contract:
    (a) Name and address of proposed contractor.
    (b) Location where contract is to be performed.
    (c) Contract number, including modification number, if possible.
    (d) Brief description of work and services to be performed.
    (e) Performance or delivery schedule.
    (f) Amount of letter contract.
    (g) Estimated total amount of definitized contract.
    (h) Type of definitive contract to be executed (fixed price, cost-
reimbursement, etc.)
    (i) Statement of the necessity and advantage to the Government of 
the use of the proposed letter contract.
    (j) Statement of percentage of the estimated cost that the 
obligation of funds represents. In rare instances where the obligation 
represents 50 percent or more of the proposed estimated cost of the 
acquisition, a justification for that obligation must be included which 
would indicate the basis and necessity for the obligation (e.g., the 
contractor requires a large initial outlay of funds for major 
subcontract awards or an extensive purchase of materials to meet an 
urgent delivery requirement). In every case, documentation must assure 
that the amount to be obligated is not in excess of an amount reasonably 
required to perform the work.
    (k) Period of effectiveness of a proposed letter contract. If more 
than 180 days, complete justification must be given.
    (l) Statement of any substantive matters that need to be resolved.



Sec. 316.603-71  Approval for modifications to letter contracts.

    All letter contract modifications (amendments) must be approved one 
level above the contracting officer. Request for authority to issue 
letter contract modifications shall be processed in the same manner as 
requests for authority to issue letter contracts and shall include the 
following:
    (a) Name and address of the contractor.
    (b) Description of work and services.
    (c) Date original request was approved and indicate approving 
official.
    (d) Letter contract number and date issued.
    (e) Complete justification as to why the letter contract cannot be 
definitized at this time.
    (f) Complete justification as to why the level of funding must be 
increased.
    (g) Complete justification as to why the period of effectiveness is 
increased beyond 180 days, if applicable.

[[Page 49]]

    (h) If the funding of the letter contract is to be increased to more 
than 50 percent of the estimated cost of the acquisition, the 
information required by 316.603-70(j) must be included.

                        Subpart 316.7_Agreements



Sec. 316.770  Unauthorized types of agreements.



Sec. 316.770-1  Letters of intent.

    A letter of intent is an informal unauthorized agreement between the 
Government and a prospective contractor which indicates that products or 
services will be produced after completion of funding and/or other 
contractual formalities. Letters of intent are often solicited by 
prospective contractors or may be originated by Government personnel. 
Letters of intent are not authorized by the FAR and are prohibited for 
use by Department personnel.



Sec. 316.770-2  Memorandums of understanding.

    A ``memorandum of understanding'' is an unauthorized agreement, 
usually drafted during the course of negotiations, to modify mandatory 
FAR and HHSAR provisions in such a manner as to make them more 
acceptable to a prospective contractor. It may be used to bind the 
contracting officer in attempting to exercise rights given the 
Government under the contract, or may contain other matters directly 
contrary to the language of the solicitation or prospective contractual 
document. Use of memorandums of understanding is not authorized. Any 
change in a solicitation or contract shall be made by amendment or 
modification to that document. When a change to a prescribed contract 
clause is considered necessary, a deviation shall be requested.

                  PART 317_SPECIAL CONTRACTING METHODS

                          Subpart 317.2_Options

Sec.

Sec. 317.201  Definition.

  Subpart 317.71_Supply and Service Acquisitions Under the Government 
                         Employees Training Act.


Sec. 317.7100  Scope of subpart.

Sec. 317.7101  Applicable regulations.

Sec. 317.7102  Acquisition of training.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4244, Jan. 17, 2001, unless otherwise noted.

                          Subpart 317.2_Options



Sec. 317.201  Definitions.

    An option must:
    (a) Identify the supplies or services as a discrete option quantity 
in addition to the basic quantity of supplies or services to be 
delivered under the initial contract award;
    (b) Establish a price or specify a method of calculation which will 
make the price certain;
    (c) Be agreed to and included in the initial contract award; and
    (d) Permit the Government the right to exercise the option 
unilaterally.

  Subpart 317.71_Supply and Service Acquisitions Under the Government 
                         Employees Training Act



Sec. 317.7100  Scope of subpart.

    This subpart provides alternate methods for obtaining training under 
the Government Employees Training Act (GETA), 5 U.S.C. Chapter 41.



Sec. 317.7101  Applicable regulations.

    Basic policy, standards, and delegations of authority to approve 
training are contained in HHS Personnel Manual Instruction 410-1.



Sec. 317.7102  Acquisition of training.

    (a) Off-the-shelf training, whether for individuals or for groups of 
employees, shall be acquired under the GETA by officials delegated 
authority in HHS Transmittal 95.5, Personnel Manual (3/30/95).
    (b) Training must be acquired through the contracting office if 
there are costs for training course development or for modification of 
off-the-shelf training courses.

[[Page 50]]



                   SUBCHAPTER D_SOCIOECONOMIC PROGRAMS

                    PART 319_SMALL BUSINESS PROGRAMS

                         Subpart 319.2_Policies

Sec.

Sec. 319.201  General policy.

               Subpart 319.5_Set-Asides for Small Business


Sec. 319.501  General.

Sec. 319.506  Withdrawing or modifying set-asides.

 Subpart 319.7_Subcontracting With Small Business, Small Disadvantaged 
            Business and Women-Owned Small Business Concerns


Sec. 319.705  Responsibilities of the contracting officer under the 
          subcontracting assistance program.

Sec. 319.705-5  Awards involving subcontracting plans.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4244, Jan. 17, 2001, unless otherwise noted.

                         Subpart 319.2_Policies



Sec. 319.201  General policy.

    (d) The functional management responsibilities for the Department's 
Small Business Program, (small, HUBZone, small disadvantaged, and women-
owned small business programs) are delegated to the Director of the 
Office of Small and Disadvantaged Business Utilization (OSDBU).
    (e) (1) The Department's Small Business Program shall be carried out 
by appointed small business specialists (SBS) at the OPDIV Level. 
Appointments, and termination of appointments, shall be made in writing 
by the head of the OPDIV after consultation and concurrence by the 
Director, OSDBU. The small business specialist shall be responsible 
directly to the appointing authority and shall be at an organizational 
level outside the direct acquisition chain of command, i.e., should 
report directly to the head of the OPDIV or designee. The Director, 
OSDBU will exercise functional management authority over small business 
specialists regarding the small business programs.
    (2) The head of each OPDIV shall appoint a qualified full-time small 
business specialist (SBS) in the following activities: Administration 
for Children and Families (ACF), Agency for Healthcare Research and 
Quality (AHRQ), Health Care Financing Administration (HCFA), Substance 
Abuse and Mental Health Services Administration (SAMHSA), Food and Drug 
Administration (FDA), Health Resources and Services Administration 
(HRSA), Indian Health Service (IHS), National Institutes of Health 
(NIH), Centers for Disease Control and Prevention (CDCP), and Program 
Support Center (PSC). A SBS shall also be appointed for the Office of 
the Secretary (OS). As deemed necessary, additional small business 
specialists may be appointed in larger contracting activities. When the 
volume of contracting does not warrant assignment of a full-time SBS, an 
individual shall be appointed as the specialist on a part-time basis. 
The responsibilities of this assignment shall take precedence over other 
responsibilities.

               Subpart 319.5_Set-Asides For Small Business



Sec. 319.501  General.

    (d) Subsequent to the contracting officer's recommendation on Form 
HHS653, Small Business Set-Aside Review Form, the SBS shall review each 
proposed acquisition and either concur or non-concur with the 
contracting officer's recommendation. If the contracting officer 
disapproves the SBS's set-aside recommendation, the reasons must be 
documented on the Form HHS-653, and the form placed in the contract 
file. The contracting officer will make the final determination as to 
whether the proposed acquisition will be set-aside or not.

[[Page 51]]



Sec. 319.506  Withdrawing or modifying set-asides.

    (d) Immediately upon notice from the contracting officer, the SBS 
shall provide telephone notification regarding all set-aside withdrawals 
to the OSDBU Director.

 Subpart 319.7_Subcontracting With Small Business, Small Disadvantaged 
            Business and Women-Owned Small Business Concerns



Sec. 319.705  Responsibilities of the contracting officer under the 
          subcontracting assistance program.



Sec. 319.705-5  Awards involving subcontracting plans.

    (a)(3) The SBA PCR shall be allowed a period of one to five working 
days to review the contract award package, depending upon the 
circumstances and complexity of the individual acquisition.

 PART 323_ENVIRONMENT, CONSERVATION, OCCUPATIONAL SAFETY, AND DRUG-FREE 
                                WORKPLACE

                    Subpart 323.70_Safety and Health

Sec.

Sec. 323.7000  Scope of subpart.

Sec. 323.7001  Policy.

Sec. 323.7002  Actions required.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4245, Jan. 17, 2001, unless otherwise noted.

                    Subpart 323.70_Safety and Health



Sec. 323.7000  Scope of subpart.

    This subpart prescribes the use of a safety and health clause in 
contracts involving hazardous materials or operations, and provides 
procedures for administering safety and health provisions.



Sec. 323.7001  Policy.

    Various statutes and regulations (e.g. Walsh-Healy Act; Service 
Contract Act) require adherence to minimum safety and health standards 
by contractors engaged in potentially hazardous work. The guidance 
contained in FAR subpart 23.3 shall be used for hazardous materials as 
the primary reference. When the guidance is judged insufficient or does 
not meet the safety and health situation in the instant acquisition, 
this subpart shall be followed.



Sec. 323.7002  Actions required.

    (a) Contracting activities. Contracting activities shall use the 
clause set forth in 352.223-70, or a clause reading substantially the 
same, in prospective contracts and subcontracts involving hazardous 
materials or operations for the following:
    (1) Services or products;
    (2) Research, development, or test projects;
    (3) Transportation of hazardous materials; and
    (4) Construction, including construction of facilities on the 
contractor's premises.
    (b) Safety officers. OPDIV safety officers shall advise and assist 
initiators of acquisition requests and contracting officers in:
    (1) Determining whether safety and health provisions should be 
included in a prospective contract;
    (2) Evaluating a prospective contractor's safety and health 
programs; and
    (3) Conducting post-award reviews and surveillance to the extent 
deemed necessary.
    (c) Initiators. Initiators of acquisition requests for items 
described in paragraph (a) of this section shall:
    (1) During the preparation of a request for contract, and in the 
solicitation, ensure that hazardous materials and operations to be used 
in the performance of the contract are clearly identified; and
    (2) During the period of performance:
    (i) Apprise the contracting office of any noncompliance with safety 
and health provisions identified in the contract; and
    (ii) Cooperate with the safety officer in conducting review and 
surveillance activities.

[[Page 52]]

        PART 324_PROTECTION OF PRIVACY AND FREEDOM OF INFORMATION

             Subpart 324.1_Protection of Individual Privacy

Sec.

Sec. 324.100  Scope of subpart.

Sec. 324.102  General.

Sec. 324.103  Procedures.

                Subpart 324.2_Freedom of Information Act


Sec. 324.202  Policy.

              Subpart 324.70_Confidentiality of Information


Sec. 324.7001  General.

Sec. 324.7002  Policy.

Sec. 324.7003  Applicability.

Sec. 324.7004  Required clause.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4245, Jan. 17, 2001, unless otherwise noted.

             Subpart 324.1_Protection of Individual Privacy



Sec. 324.100  Scope of subpart.

    This subpart implements 45 CFR Part 5b, Privacy Act Regulations, and 
FAR Subpart 24.1, Protection of Individual Privacy, which implements the 
Privacy Act of 1974 (Public Law 93-579, December 31, 1974; 5 U.S.C. 
552a) and OMB Circular No. A-108, July 9, 1975.



Sec. 324.102  General.

    (a) It is the Department's policy to protect the privacy of 
individuals to the maximum possible extent while permitting the exchange 
of records required to fulfill the Department's administrative and 
program responsibilities and its responsibilities for disclosing records 
to which the general public is entitled under the Freedom of Information 
Act (5 U.S.C. 552). The Privacy Act of 1974 and the Department's 
implementation under 45 CFR part 5b apply ``when an agency provides by a 
contract for the operation by or on behalf of the agency of a system of 
records to accomplish any agency function* * *'' The key factor is 
whether a departmental function is involved. Therefore, the Privacy Act 
requirements apply to a departmental contract when, under the contract, 
the contractor must maintain or operate a system of records to 
accomplish a departmental function.
    (e) The program official, and, as necessary, the official designated 
as the activity's Privacy Act Coordinator and the Office of General 
Counsel, shall determine the applicability of the Act to each proposed 
acquisition. The program official is required to include a statement in 
the request for contract indicating whether the Privacy Act is or is not 
applicable to the proposed acquisition.
    (f) Whenever the contracting officer is informed that the Privacy 
Act is not applicable, but the resultant contract will involve the 
collection of individually identifiable personal data by the contractor, 
the contracting officer shall include provisions to protect the 
confidentiality of the records and the privacy of individuals identified 
in the records (see subpart 324.70).



Sec. 324.103  Procedures.

    (a) All requests for contract shall be reviewed by the contracting 
officer to determine whether the Privacy Act requirements are 
applicable. If applicable, the contracting officer shall include the 
solicitation notification and contract clause required by FAR 24.104 in 
the solicitation, and the contract clause in the resultant contract. In 
addition, the contracting officer shall ensure that the solicitation 
notification, contract clause, and other pertinent information specified 
in this subpart are included in any contract modification which results 
in the Privacy Act requirements becoming applicable to a contract.
    (b)(1) The contracting officer shall identify the system(s) of 
records on individuals in solicitations, contracts, and contract 
modifications to which the Privacy Act and the implementing regulations 
are applicable.
    (2) The contracting officer shall include a statement in the 
contract notifying the contractor that the contractor and its employees 
are subject to criminal penalties for violations of the Act (5 U.S.C. 
552a(i)) to the same extent as employees of the Department. The 
statement shall require that

[[Page 53]]

the contractor assure that each contractor employee knows the prescribed 
rules of conduct, and each contractor employee is aware that he/she can 
be subjected to criminal penalties for violations of the Act. The 
contracting officer shall provide the contractor with a copy of the 
rules of conduct and other requirements set forth in 45 CFR part 5b.
    (c) The contracting officer shall include in the contract the 
disposition to be made of the system(s) of records on individuals upon 
completion of performance of the contract. For example, the contract may 
require the contractor to completely destroy the records, to remove 
personal identifiers, to turn the records over to the Department, or to 
keep the records but take certain measures to keep the records 
confidential and protect the individuals' privacy.
    (d) Whenever an acquisition is determined to be subject to the 
Privacy Act requirements, a ``system notice,'' prepared by the program 
official and describing the Department's intent to establish a new 
system of records on individuals, to make modifications to an existing 
system, or to disclose information in regard to an existing system, is 
required to be published in the Federal Register. A copy of the ``system 
notice'' shall be attached to the request for contract or purchase 
request. If a ``system notice'' is not attached, the contracting officer 
shall inquire about its status and shall obtain a copy from the program 
official for inclusion in the contract file. If a ``system notice'' has 
not been published in the Federal Register, the contracting officer may 
proceed with the acquisition but shall not award the contract until the 
``system notice'' is published, and publication is verified by the 
contracting officer.

                Subpart 324.2_Freedom of Information Act



Sec. 324.202  Policy.

    (a) The Department's regulation implementing the Freedom of 
Information Act (FOIA), 5 U.S.C. 552, as amended, is set forth in 45 CFR 
part 5.
    (b) The contracting officer, upon receiving a FOIA request, shall 
follow Department and operating division procedures. As necessary, 
actions should be coordinated with the cognizant Freedom of Information 
(FOI) Officer and the Business and Administrative Law Division of the 
Office of General Counsel. The contracting officer must remember that 
only the FOI Officer has the authority to release or deny release of 
records. While the contracting officer should be familiar with the 
entire FOIA regulation in 45 CFR part 5, particular attention should be 
focused on Secs. 5.65 and 5.66; also of interest are Secs. 5.32, 5.33, 
and 5.35.

              Subpart 324.70_Confidentiality of Information



Sec. 324.7001  General.

    In performance of certain HHS contracts, it is necessary for the 
contractor to generate data, or be furnished data by the Government, 
which is about individuals, organizations, or Federal programs. This 
subpart and the accompanying contract clause require contractors to 
prudently handle disclosure of certain types of information not subject 
to the Privacy Act or the HHS human subject regulations set forth in 45 
CFR part 46. This subpart and contract clause address the kinds of data 
to be generated by the contractor and/or data to be furnished by the 
Government that are considered confidential and how it should be 
treated.



Sec. 324.7002  Policy.

    It is the policy of HHS to protect personal interests of 
individuals, corporate interests of non-governmental organizations, and 
the capacity of the Government to provide public services when 
information from or about individuals, organizations, or Federal 
agencies is provided to or obtained by contractors in performance of HHS 
contracts. This protection depends on the contractor's recognition and 
proper handling of the information. As a result, the ``Confidentiality 
of Information'' contract clause was developed.



Sec. 324.7003  Applicability.

    (a) The ``Confidentiality of Information'' clause, set forth in 
352.224-70,

[[Page 54]]

should be used in solicitations and resultant contracts whenever the 
need exists to keep information confidential. Examples of situations 
where the clause may be appropriate include:
    (1) Studies performed by the contractor which generate information 
or involve Government-furnished information that is personally 
identifiable, such as medical records, vital statistics, surveys, and 
questionnaires;
    (2) Contracts which involve the use of salary structures, wage 
schedules, proprietary plans or processes, or confidential financial 
information of organizations other than the contractor's; and
    (3) Studies or research which may result in preliminary or 
invalidated findings which, upon disclosure to the public, might create 
erroneous conclusions which, if acted upon, could threaten public health 
or safety.
    (b) With regard to protecting individuals, this subpart and contract 
clause are not meant to regulate or control the method of selecting 
subjects and performing studies or experiments involving them. These 
matters are dealt with in the HHS regulation entitled ``Protection of 
Human Subjects,'' 45 CFR Part 46. If a system of records under contract, 
or portions thereof, is determined to be subject to the requirements of 
the Privacy Act, in accordance with FAR 24.1 and 324.1 and Title 45 CFR 
part 5b, the procedures cited in those references are applicable and the 
Privacy Act contract clause shall be included in the contract. If the 
contract also involves confidential information, as described in this 
section, which is not subject to the Privacy Act, the contract shall 
include the ``Confidentiality of Information'' clause in addition to the 
Privacy Act clause.



Sec. 324.7004  Required clause.

    The clause set forth in 352.224-70 shall be included in any RFP and 
resultant contract(s) where it has been determined that confidentiality 
of information provisions may apply. Any RFP announcing the intent to 
include this clause in any resultant contract(s) shall indicate, as 
specifically as possible, the types of data which would be covered and 
requirements for handling the data.

                      PART 325_FOREIGN ACQUISITION

                 Subpart 325.1_Buy American Act_Supplies

Sec.

Sec. 325.102  Policy.

Sec. 325.108  Excepted articles, materials, and supplies.

                Subpart 325.3_Balance of Payments Program


Sec. 325.302  Policy.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4247, Jan. 17, 2001, unless otherwise noted.

                 Subpart 325.1_Buy American Act_Supplies



Sec. 325.102  Policy.

    (b) The head of the contracting activity (not delegable) shall make 
the determinations required by FAR 25.102(a)(1) through (5) and 
25.102(b)(2).



Sec. 325.108  Excepted articles, materials, and supplies.

    (b) Articles, materials, and supplies not listed in FAR 25.108(d) 
may be excepted only after a written determination has been made by the 
head of the contracting activity (not delegable). These determinations 
are required only in instances where it has been determined that only 
suppliers of foreign source end items shall be solicited. However, 
approvals and determinations covering individual acquisitions in the 
following categories may be made by the contracting officer:
    (1) Acquisition of spare and replacement parts for foreign 
manufactured items, if the acquisition must be restricted to the 
original manufacturer or its supplier; and
    (2) Acquisition of foreign drugs when it has been determined, in 
writing, by the responsible program official, that only the requested 
foreign drug will fulfill the requirement.

[[Page 55]]

                Subpart 325.3_Balance of Payments Program



Sec. 325.302  Policy.

    All determinations addressed in FAR 25.302 shall be made by the head 
of the contracting activity (not delegable).

[[Page 56]]



              SUBCHAPTER E_GENERAL CONTRACTING REQUIREMENTS

                      PART 328_BONDS AND INSURANCE

                         Subpart 328.3_Insurance

Sec.

Sec. 328.301  Policy.

Sec. 328.311  Solicitation provision and contract clause on liability 
          insurance under cost-reimbursement contracts.

Sec. 328.311-2  Agency solicitation provisions and contract clauses.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4247, Jan. 17, 2001, unless otherwise noted.

                         Subpart 328.3_Insurance



Sec. 328.301  Policy.

    It is Department policy to limit the Government's reimbursement of 
its contractors' liability to third persons for claims not covered by 
insurance in cost-reimbursement contracts to the Limitation of Funds or 
Limitation of Cost clause of the contract. In addition, the amount of 
the Government's reimbursement will be limited to final judgments or 
settlements approved in writing by the Government.



Sec. 328.311  Solicitation provision and contract clause on liability 
          insurance under cost-reimbursement contracts.



Sec. 328.311-2  Agency solicitation provisions and contract clauses.

    The contracting officer shall insert the clause at 352.228-7, 
Insurance--Liability to Third Persons, in all solicitations and 
resulting cost-reimbursement contracts, in lieu of the clause at FAR 
52.228-7 required by FAR 28.311-1. This is an authorized deviation.

                   PART 330_COST ACCOUNTING STANDARDS

                 Subpart 330.2_CAS Program Requirements

Sec.

Sec. 330.201  Contract requirements.

Sec. 330.201-5  Waiver.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4247, Jan. 17, 2001, unless otherwise noted.

                 Subpart 330.2_CAS Program Requirements



Sec. 330.201  Contract requirements.



Sec. 330.201-5  Waiver.

    (c) The requirements of FAR 30.201-5 shall be exercised by the 
Director, Office of Acquisition Management (DOAM). Requests for waivers 
shall be forwarded through normal acquisition channels to the DOAM.

                       PART 332_CONTRACT FINANCING

         Subpart 332.4_Advance Payments for Non-Commercial Items

Sec.

Sec. 332.402  General.

Sec. 332.403  Applicability.

Sec. 332.407  Interest.

Sec. 332.409  Contracting officer action.

Sec. 332.409-1  Recommendation for approval.

             Subpart 332.5_Progress Payments Based on Costs


Sec. 332.501  General.

Sec. 332.501-2  Unusual progress payments.

                     Subpart 332.7_Contract Funding


Sec. 332.702  Policy.

Sec. 332.703  Contract funding requirements.

Sec. 332.703-1  General.

Sec. 332.704  Limitations of cost or funds.

Sec. 332.705  Contract clauses.

Sec. 332.705-2  Clauses for limitation of costs or funds.

                      Subpart 332.9_Prompt Payment


Sec. 332.902  Definitions.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4247, Jan. 17, 2001, unless otherwise noted.

         Subpart 332.4_Advance Payments for Non-Commercial Items



Sec. 332.402  General.

    (e) The determination that the making of an advance payment is in 
the

[[Page 57]]

public interest (see FAR 32.402(c)(1)(iii)(A)) shall be made by the 
respective chief of the contracting office (CCO)(not delegable).



Sec. 332.403  Applicability.

    All contracts for research work with educational institutions 
located in the United States shall provide for financing by use of 
advance payments, in reasonable amounts, unless otherwise prohibited by 
law.



Sec. 332.407  Interest.

    (d) The HCA (not delegable) is authorized to make the determinations 
in FAR 32.407(d) and as follows. In addition to the interest-free 
advance payments for the types of contracts listed in FAR 32.407(d), 
advance payments without interest may be approved for nonprofit 
contracts which are without fee with educational institutions and other 
nonprofit organizations, whether public or private, which are for the 
performance of work involving health services, educational programs, or 
social service programs, including, but not limited to, programs such 
as:
    (1) Community health representative services for an Indian Tribe or 
Band;
    (2) Narcotic addict rehabilitative services;
    (3) Comprehensive health care service program for Model Neighborhood 
programs;
    (4) Planning and development of health maintenance organizations;
    (5) Dissemination of information derived from educational research;
    (6) Surveys or demonstrations in the field of education;
    (7) Producing or distributing educational media for handicapped 
persons including captioned films for the hearing impaired;
    (8) Operation of language or area centers;
    (9) Conduct of biomedical research and support services;
    (10) Research surveys or demonstrations involving the training and 
placement of health manpower and health professionals, and dissemination 
of related information; and
    (11) Surveys or demonstrations in the field of social service.



Sec. 332.409  Contracting officer action.



Sec. 332.409-1  Recommendation for approval.

    The information in FAR 32.409-1 (or FAR 32.409-2) shall be 
transmitted to the HCA in the form of a briefing memorandum.

              Subpart 332.5_Progress Payments Based on Cost



Sec. 332.501  General.



Sec. 332.501-2  Unusual progress payments.

    (a)(3) The approval of an unusual progress payment shall be made by 
the head of the contracting activity (HCA)(not delegable).

                     Subpart 332.7_Contract Funding



Sec. 332.702  Policy.

    An incrementally funded contract is a contract in which the total 
work effort is to be performed over multiple time periods and funds are 
allotted to cover discernible phases or increments of performance.
    (a) Incremental funding may be applied to cost-reimbursement type 
contracts for the acquisition of research and development and other 
types of nonpersonal, nonseverable services. It shall not be applied to 
contracts for construction services, architect-engineer services, or 
severable services.Incremental funding allows nonseverable cost-
reimbursement contracts, awarded for more than one year, to be funded 
from succeeding fiscal years.
    (b) It is departmental policy that contracts for projects of 
multiple year duration be fully funded, whenever possible, to cover the 
entire project. However, incrementally funded contracts may be used 
when:
    (1) A project, which is part of an approved program, is anticipated 
to be of multiple year duration, but funds are not currently available 
to cover the entire project;
    (2) The project represents a valid need for the fiscal year in which 
the contract is awarded and of the succeeding fiscal years of the 
project's duration, during which additional funds

[[Page 58]]

may be obligated by increasing the allotment to the contract;
    (3) The project is so significant to the approved program that there 
is reasonable assurance that it will command a high priority for 
proposed appropriations to cover the entire multiple year duration; and
    (4) The statement of work is specific and is defined by separate 
phases or increments so that, at the completion of each, progress can be 
effectively measured.



Sec. 332.703  Contract funding requirements.



Sec. 332.703-1  General.

    (b) The following general guidelines are applicable to incrementally 
funded contracts:
    (1) The estimated total cost of the project (all planned phases or 
increments) is to be taken into consideration when determining the 
requirements which must be met before entering into the contract; i.e., 
justification for noncompetitive acquisition, approval or award, etc.
    (2) The RFP and resultant contract are to include a statement of 
work which describes the total project covering the proposed multiple 
year period of performance and indicating timetables consistent with 
planned phases or increments and corresponding allotments of funds.
    (3) Offerors will be expected to respond to RFPs with technical and 
cost proposals for the entire project indicating distinct break-outs of 
the planned phases or increments, and the multiple year period of 
performance.
    (4) Negotiations will be conducted based upon the total project, 
including all planned phases or increments, and the multiple year period 
of performance.
    (5) Sufficient funds must be obligated under the basic contract to 
cover no less than the first year of performance, unless the contracting 
officer determines it is advantageous to the Government to fund the 
contract for a lesser period. In that event, the contracting officer 
shall ensure that the obligated funds are sufficient to cover a complete 
phase or increment of performance representing a material and measurable 
part of the total project, and the contract period shall be reduced 
accordingly.
    (6) Because of the magnitude of the scope of work and multiple year 
period of performance under an incrementally funded contract, there is a 
critical need for careful program planning. Program planning must 
provide for appropriate surveillance of the contractor's performance and 
adequate controls to ensure that projected funding will not impinge on 
the program office's ability to support, within anticipated 
appropriations, other equally important contract or grant programs.
    (7) An incrementally funded contract must contain precise 
requirements for progress reports to enable the project officer to 
effectively monitor the contract. The project officer should be required 
to prepare periodic performance evaluation reports to facilitate the 
program office's ultimate decision to allot additional funds under the 
contract.



Sec. 332.704  Limitation of cost or funds.

    For detailed instruction regarding administrative actions in 
connection with anticipated cost overruns, see subpart 342.71



Sec. 332.705  Contract clauses.



Sec. 332.705-2  Clauses for limitation of costs or funds.

    (c)(1) When using the Limitation of Funds clause (FAR 52.232-22) in 
the solicitation and resultant incrementally funded contract, the 
contracting officer shall insert the following legend between the clause 
title and the clause text:

(This clause supersedes the Limitation of Cost clause found in the 
General Provisions of this contract.)

    (2) The contracting officer shall also include a clause reading 
substantially as that shown in 352.232-74 in the Special Provisions of 
the resultant incrementally funded contract.
    (3) The request for proposals must inform prospective offerors of 
the Department's intention to enter into an incrementally funded 
contract. Therefore, the contracting officer shall include the provision 
at 352.232-75 in the request for proposals whenever the use

[[Page 59]]

of incremental funding is contemplated.

                      Subpart 332.9_Prompt Payment



Sec. 332.902  Definitions.

    Fiscal office means the office responsible for: determining whether 
interest penalties are due a contractor and, if so, the amount; 
determining whether an invoice offers a financially advantageous 
discount; maintaining records for and submission of prompt payment 
reports to the Deputy Assistant Secretary, Finance (DASF), ASMB, OS; and 
processing payments to the Treasury Department to allow for payment to a 
contractor when due. The fiscal office may fulfill the roles of the 
``designated billing office'' and the ``designated payment office.''

                PART 333_PROTESTS, DISPUTES, AND APPEALS

                         Subpart 333.1_Protests

Sec.

Sec. 333.102  General.

Sec. 333.103  Protests to the agency.

Sec. 333.104  Protests to GAO.

                   Subpart 333.2_Disputes and Appeals


Sec. 333.203  Applicability.

Sec. 333.209  Suspected fraudulent claims.

Sec. 333.211  Contracting officer's decision.

Sec. 333.212  Contracting officer's duties upon appeal.

Sec. 333.212-70  Formats.

Sec. 333.213  Obligation to continue performance.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4249, Jan. 17, 2001, unless otherwise noted.

                         Subpart 333.1_Protests



Sec. 333.102  General.

    (a) Contracting officers shall consider all protests or objections 
regarding the award of a contract, whether submitted before or after 
award, provided the protests are filed in a timely manner and are 
submitted by interested parties. To be considered timely, protests based 
on alleged improprieties in any type of solicitation which are apparent 
before bid opening or the closing date for receipt of proposals shall be 
filed prior to bid opening or the closing date for receipt of proposals. 
In the case of negotiated acquisitions, alleged improprieties which do 
not exist in initial solicitations, but which are subsequently 
incorporated by amendment, must be protested not later than the next 
closing date for receipt of proposals following the incorporation of the 
amendment. In other cases, protests shall be filed not later than ten 
(10) calendar days after the basis for protest is known or should have 
been known, whichever is earlier. Provided a protest has been filed 
initially with the contracting officer, any subsequent protest to the 
Secretary or GAO filed within ten (10) calendar days of notification of 
adverse action will be considered. Written confirmation of all oral 
protests shall be requested from protestants and must be timely filed.
    (g)(1) The Office of Acquisition Management (OAM) has been 
designated as the headquarters office to serve as the liaison for 
protests lodged with GAO. Within the OAM, the Departmental Protest 
Control Officer (DPCO) has been designated as the individual to be 
contacted by GAO.
    (2) Each contracting activity shall designate a protest control 
officer to serve as an advisor to the contracting officer and to monitor 
protests from the time of initial notification until the protest has 
been resolved. The protest control officer should be a senior 
acquisition specialist in the headquarters acquisition staff office. In 
addition, contracting activities should designate similar officials 
within their principal components to the extent practicable and 
feasible. A copy of each appointment and termination of appointment of 
protest control officers shall be forwarded to the Director, OAM.



Sec. 333.103  Protests to the agency.

    (f)(1) The contracting officer is authorized to make the 
determination, using the criteria in FAR 33.104(b), to award a contract 
notwithstanding the protest after obtaining the concurrence of the 
contracting activity's protest control officer and the Office of General 
Counsel--Business and Administrative Law Division (OGC-BAL). If the 
protest has been lodged with the Secretary, is addressed to the 
Secretary,

[[Page 60]]

or requests referral to the Secretary, approval shall also be obtained 
from the Director, OAM before making the award.
    (2) The contracting officer shall require written confirmation of 
any oral protest. To be considered timely, the written confirmation must 
be filed in accordance with the applicable provisions in 333.102(a). In 
the following cases, written protests received by the contracting 
officer before award shall be forwarded, through acquisition channels, 
to the DPCO for processing. Files concerning these protests shall be 
submitted in duplicate, or as otherwise specified by the DPCO and sent 
in the most expeditious manner, marked ``IMMEDIATE ACTION--PROTEST 
BEFORE AWARD'', and contain the documentation referenced in 
333.104(a)(3).
    (i) The protestant requests referral to the Secretary of Health and 
Human Services;
    (ii) The protest is known to have been lodged with the Comptroller 
General or the Secretary, or is addressed to either; or
    (iii) The contracting officer entertains some doubt as to the proper 
action regarding the protest or believes it to be in the best interest 
of the Government that the protest be considered by the Secretary or the 
Comptroller General. Otherwise, protests addressed to the contracting 
officer may be answered by the contracting officer, with the concurrence 
of the contracting activity's protest control officer and OGC-BAL.
    (3) Protests received after award shall be treated as indicated in 
FAR 33.103(b)(3).



Sec. 333.104  Protests to GAO.

    (a) General procedures. (3) Protests lodged with GAO, whether before 
or after award, shall be processed by the DPCO. Protest files shall be 
prepared by the contracting office and distributed as follows: two 
copies to the DPCO, one copy to the contracting activity's protest 
control officer, and one copy to OGC-BAL. Files shall include the 
following documentation:
    (i) The contracting officer's statement of facts and circumstances, 
including a discussion of the merits of the protest, and conclusions and 
recommendations, including documentary evidence on which they are based.
    (ii) A copy of the IFB or RFP.
    (iii) A copy of the abstract of bids or proposals.
    (iv) A copy of the bid or proposal of the successful offeror to whom 
award has been made or is proposed to be made.
    (v) A copy of the bid or proposal of the protestant, if any.
    (vi) The current status of award. When award has been made, this 
shall include whether performance has commenced, shipment or delivery 
has been made, or a stop work order has been issued.
    (vii) A copy of any mutual agreement to suspend work on a no-cost 
basis, when appropriate (see FAR 33.104(c)(4)).
    (viii) Copies of the notice of protest given offerors and other 
parties when the notice is appropriate (see FAR 33.104(a)(2)).
    (ix) A copy of the technical evaluation report, when applicable, and 
a copy of each evaluator's rating for relevant proposals.
    (x) A copy of the negotiation memorandum, when applicable.
    (xi) The name and telephone number of the person in the contracting 
office who may be contacted for information relevant to the protest.
    (xii) A copy of the competitive range memorandum. and
    (xiii) Any document which is referred to in the contracting 
officer's statement of facts. The files shall be assembled in an orderly 
manner and shall include an index of enclosures.
    (4) The DPCO is responsible for making the necessary distributions 
referenced in FAR 33.104 (a)(4).
    (5) The contracting officer shall furnish the protest file 
containing the documentation specified in paragraph (a)(3) of this 
section, except the item in paragraph (a)(3)(i), to the DPCO within 
fourteen (14) calendar days from receipt of the protest. The contracting 
officer shall provide the documentation required by item (a)(3)(i) of 
this section to the DPCO within twenty-one (21) calendar days from 
receipt of the protest. Since the statute allows only a short time 
period in which to respond

[[Page 61]]

to protests lodged with GAO, the contracting officer shall handle each 
protest on a priority basis. The DPCO shall prepare the report and 
submit it and the protest file to GAO in accordance with FAR 
33.104(a)(4)(i).
    (6) Since the DPCO will furnish the report to GAO, the protestor, 
and other interested parties, comments on the report from the protestor 
and other interested parties will be requested to be sent to the DPCO.
    (7) The Office of Acquisition Management (OAM) has been designated 
as the headquarters office, and the DPCO as the individual, that GAO 
should contact concerning all protests lodged with GAO.
    (b) Protests before award. (1) To make an award notwithstanding a 
protest, the contracting officer shall prepare a finding using the 
criteria in FAR 33.104(b)(1), have it executed by the head of the 
contracting activity (HCA)(not delegable), and forward it, along with a 
written request for approval to make the award, to the Deputy Assistant 
Secretary for Grants and Acquisition Management (DASGAM).
    (2) If the request to make an award notwithstanding the protest is 
approved by the DASGAM, the DPCO shall notify GAO. Whether the request 
is approved or not, the DPCO shall telephonically notify the contracting 
activity's protest control officer of the decision of the DASGAM, and 
the contracting activity's protest control officer shall immediately 
notify the contracting officer. The DPCO shall confirm the decision by 
memorandum to the contracting activity's protest control officer.
    (4) The contracting officer shall prepare the protest file in 
accordance with paragraph (a)(3) of this section, and forward the 
required number of copies to the DPCO (see paragraph (a)(5) of this 
section).
    (c) Protests after award. (2) If the contracting officer believes 
performance should be allowed to continue notwithstanding the protest, a 
finding shall be prepared by the contracting officer using the criteria 
in FAR 33.104(c)(2), executed by the HCA (not delegable), and forwarded, 
along with a written request for approval, to the Director, OAM. The 
same procedures for notification stated in paragraph (b)(2) of this 
section shall be followed.
    (6) The contracting officer shall prepare the protest file in 
accordance with paragraph (a)(3) of this section, and forward the 
required number of copies to the DPCO (see paragraph (a)(5) of this 
section).
    (d) Findings and notice. The contracting officer shall perform the 
actions required by FAR 33.104 (d); however, notification to GAO and 
other interested parties shall be made by the DPCO.
    (g) Notice to GAO. The Deputy Assistant Secretary for Grants and 
Acquisition Management shall be the official to comply with the 
requirements of FAR 33.104 (g).
    (i) Express option. When GAO invokes the express option, the 
contracting officer shall prepare the complete protest file as described 
in paragraph (a)(3) of this section, to include the item in paragraph 
(a)(3)(i), and deliver it (hand-carry, if necessary) to the DPCO in time 
to meet the submittal date established by GAO. The DPCO will notify the 
contracting officer of the submittal date after GAO has finalized its 
requirements.

                   Subpart 333.2_Disputes and Appeals



Sec. 333.203  Applicability.

    (c) The Armed Services Board of Contract Appeals (ASBCA) has been 
designated by the Secretary as the authorized ``Board'' to hear and 
determine disputes for the Department.



Sec. 333.209  Suspected fraudulent claims.

    The contracting officer shall submit any instance of a contractor's 
suspected fraudulent claim to the Office of the Inspector General for 
investigation.



Sec. 333.211  Contracting officer's decision.

    (a)(2) The contracting officer shall refer a proposed final decision 
to the Office of General Counsel, Business and Administrative Law 
Division (OGC-BAL), for advice as to the legal sufficiency and format 
before sending the final decision to the contractor. The contracting 
officer shall provide OGC-BAL with the pertinent documents

[[Page 62]]

with the submission of each proposed final decision.
    (a)(4)(v) When using the paragraph in FAR 33.211 (a)(4)(v), the 
contracting officer shall insert the words ``Armed Services'' before 
each mention of the term ``Board of Contract Appeals''.
    (h) At any time within the period of appeal, the contracting officer 
may modify or withdraw his/her final decision. If an appeal from the 
final decision has been taken to the ASBCA, the contracting officer will 
forward his/her recommended action to OGC-BAL with the supplement to the 
contract file which supports the recommended correction or amendment.



Sec. 333.212  Contracting officer's duties upon appeal.

    (a) Appeals shall be governed by the rules set forth in the ``Rules 
of the Armed Services Board of Contract Appeals'', or by the rules 
established by the U.S. Court of Federal Claims, as appropriate.
    (b) OGC-BAL is designated as the Government Trial Attorney to 
represent the Government in the defense of appeals before the ASBCA. A 
decision by the ASBCA will be transmitted by the Government Trial 
Attorney to the appropriate contracting officer for compliance in 
accordance with the ASBCA's decision.
    (c) If an appeal is filed with the ASBCA, the contracting officer 
shall assemble a file within 30 days of receipt of an appeal, or advice 
that an appeal has been filed, that consists of all documents pertinent 
to the appeal, including:
    (1) The decision and findings of fact from which the appeal is 
taken;
    (2) The contract, including specifications and pertinent 
modifications, plans and drawings;
    (3) All correspondence between the parties pertinent to the appeal, 
including the letter or letters of claim in response to which the 
decision was issued;
    (4) Transcripts of any testimony taken during the course of 
proceedings, and affidavits or statements of any witness on the matter 
in dispute made prior to the filing of the notice of appeal with the 
Board; and
    (5) Any additional information considered pertinent. The contracting 
officer shall furnish the appeal file to the Government Trial Attorney 
for review and approval. After approval, the contracting officer shall 
prepare four copies of the file, one for the ASBCA, one for the 
appellant, one for the Government Trial Attorney, and one for the 
contracting office.
    (d) At all times after the filing of an appeal, the contracting 
officer shall render whatever assistance is requested by the Government 
Trial Attorney. When an appeal is set for hearing, the concerned 
contracting officer, acting under the guidance of the Government Trial 
Attorney, shall be responsible for arranging for the presence of 
Government witnesses and specified physical and documentary evidence at 
both the pre-hearing conference and hearing.
    (e) If a contractor which has filed an appeal with the ASBCA elects 
to accept fully the decision from which the appeal was taken, or any 
modification to it, and gives written notification of acceptance to the 
Government Trial Attorney or the concerned contracting officer, the 
Government Trial Attorney will notify the ASBCA of the disposition of 
the dispute in accordance with Rule 27 of the ASBCA.
    (f) If the contractor has elected to appeal to the U.S. Court of 
Federal Claims, the U.S. Department of Justice will represent the 
Department. However, the contracting officer shall still coordinate all 
actions through OGC-BAL.



Sec. 333.212-70  Formats.

    (a) The following format is suggested for use in transmitting appeal 
files to the ASBCA:

Your reference:_________________________________________________________
(Docket No.)

(Name)

Recorder, Armed Services Board of Contract Appeals

Skyline Six
5109 Leesburg Pike
Falls Church, Virginia 22041
Dear (Name):
    Transmitted herewith are documents relative to the appeal under 
Contract No. ___ with the ______
(Name of contractor)


[[Page 63]]


in accordance with the procedures under Rule 4. The Government Trial 
Attorney for this case is

_______________________________________________________________________

_______________________________________________________________________

(Insert Division of Business and Administrative Law, Office of General 
Counsel, Department of Health and Human Services, 330 Independence 
Avenue, SW., Washington, DC 20201).

The request for payment of charges resulting from the processing of this 
appeal should be addressed to:
_______________________________________________________________________
(Insert name and address of cognizant finance office.)
_______________________________________________________________________
Sincerely yours,

Contracting Officer
Enclosures

    (b) The following format is suggested for use in notifying the 
appellant that the appeal file was submitted to the ASBCA:

(Contractor Address)
_______________________________________________________________________

_______________________________________________________________________

Dear ___:
    An appeal file has been compiled relative to the appeal under 
Contract No. ___, and has been submitted to the Armed Services Board of 
Contract Appeals (ASBCA). The enclosed duplicate of the appeal file is 
identical to that submitted to the Board, except that contract documents 
which you already have been excluded. You may furnish or suggest any 
additional information deemed pertinent to the appeal to the Armed 
Services Board of Contract Appeals according to their rules.
    The ASBCA will provide you with further information concerning this 
appeal.
Sincerely yours,

Contracting Officer
Enclosure



Sec. 333.213  Obligation to continue performance.

    (a) The Disputes clause at FAR 52.233-1 shall be used without the 
use of Alternate I. However, if the contracting officer determines that 
the Government's interest would be better served by use of paragraph (i) 
in Alternate I, he/she must request approval for its use from the chief 
of the contracting office.

[[Page 64]]



             SUBCHAPTER F_SPECIAL CATEGORIES OF CONTRACTING

                    PART 334_MAJOR SYSTEM ACQUISITION

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4251, Jan. 17, 2001, unless otherwise noted.



Sec. 334.003  Responsibilities.

    The Department's implementation of OMB Circular No. A-109 may be 
found in Chapter 1-150 of the General Administration Manual.

              PART 335_RESEARCH AND DEVELOPMENT CONTRACTING

Sec.

Sec. 335.070  Cost-sharing.

Sec. 335.070-1  Policy.

Sec. 335.070-2  Amount of cost-sharing.

Sec. 335.070-3  Method of cost-sharing.

Sec. 335.070-4  Contract award.

Sec. 335.071  Special determinations and findings affecting research and 
          development contracting.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4251, Jan. 17, 2001, unless otherwise noted.



Sec. 335.070  Cost-sharing.



Sec. 335.070-1  Policy.

    (a) The use of cost-sharing type contracts should be encouraged to 
contribute to the cost of performing research where there is a 
probability that the contractor will receive present or future benefits 
from participation, such as, increased technical know-how, training to 
employees, acquisition of equipment, use of background knowledge in 
future contracts, etc. Cost-sharing is intended to serve the mutual 
interests of the Government and the performing organization by helping 
to assure efficient utilization of the resources available for the 
conduct of research projects and by promoting sound planning and prudent 
fiscal policies by the performing organization. Encouragement should be 
given to organizations to contribute to the cost of performing research 
under contracts unless the contracting officer determines that a request 
for cost-sharing would not be appropriate because of the following 
circumstances:
    (1) The particular research objective or scope of effort for the 
project is specified by the Government rather than proposed by the 
performing organization. This would usually include any formal 
Government request for proposals for a specific project.
    (2) The research effort has only minor relevance to the non-Federal 
activities of the performing organization, and the organization is 
proposing to undertake the research primarily as a service to the 
Government.
    (3) The organization has little or no non-Federal sources or funds 
from which to make a cost contribution. Cost-sharing should generally 
not be requested if cost-sharing would require the Government to provide 
funds through some other means (such as fees) to enable the organization 
to cost-share. It should be recognized that those organizations which 
are predominantly engaged in research and development and have little or 
no production or other service activities may not be in a favorable 
position to make a cost contribution.
    (b) The responsibility for negotiating cost-sharing is that of the 
contracting office. Each research contract file should show whether the 
contracting officer considered cost-sharing appropriate for that 
particular contract and in what amount. If cost-sharing was not 
considered appropriate, the file must indicate the factual basis for 
that decision, e.g., ``Because the contractor will derive no benefits 
from this award that can be applied to its commercial activities, cost-
sharing is not considered appropriate.'' The contracting officer may 
wish to coordinate with the project officer before documenting this 
decision.
    (c) If the contracting officer considers cost-sharing to be 
appropriate for a research contract and the contractor refuses to accept 
this type of contract, the award may be made without cost-sharing, if 
the contracting officer concludes that payment of the

[[Page 65]]

full cost of the research effort is necessary in order to obtain the 
services of that particular contractor.



Sec. 335.070-2  Amount of cost-sharing.

    When cost-sharing is determined to be appropriate, the following 
guidelines shall be utilized in determining the amount of cost 
participation by the contractor.
    (a) The amount of cost participation should depend to a large extent 
on whether the research effort or results are likely to enhance the 
performing organization's capability, expertise, or competitive 
position, and the value of this enhancement to the performing 
organization. It should be recognized that those organizations which are 
predominantly engaged in research and development have little or no 
production or other service activities and may not be in a favorable 
position to derive a monetary benefit from their research under Federal 
agreements. Therefore, contractor cost participation could reasonably 
range from as little as 1 percent or less of the total project cost, to 
more than 50 percent of the total project cost. Ultimately, the 
contracting officer should bear in mind that cost-sharing is a 
negotiable item. As such, the amount of cost-sharing should be 
proportional to the anticipated value of the contractor's gain.
    (b) If the performing organization will not acquire title or the 
right to use inventions, patents, or technical information resulting 
from the research project, it would generally be appropriate to obtain 
less cost-sharing than in cases in which the performer acquires these 
rights.
    (c) A fee or profit will usually not be paid to the performing 
organization if the organization is to contribute to the cost of the 
research effort, but the amount of cost-sharing may be reduced to 
reflect the fact that the organization is foregoing its normal fee or 
profit in the research. However, if the research is expected to be of 
only minor value to the performing organization and if cost-sharing is 
not required by statute, it may be appropriate for the performer to make 
a contribution in the form of a reduced fee or profit rather than 
sharing costs of the project.
    (d) The organization's participation may be considered over the 
total term of the project so that a relatively high contribution in one 
year may be offset by a relatively low contribution in another.
    (e) A relatively low degree of cost-sharing may be appropriate if, 
in the view of the operating divisions or their subordinate elements, an 
area of research requires special stimulus in the national interest.



Sec. 335.070-3  Method of cost-sharing.

    Cost-sharing on individual contracts may be accomplished either by a 
contribution of part or all of one or more elements of allowable cost of 
the work being performed, or by a fixed amount or stated percentage of 
the total allowable costs of the project. Costs so contributed may not 
be charged to the Government under any other grant or contract 
(including allocations to other grants or contracts as part of any 
independent research and development program).



Sec. 335.070-4  Contract award.

    In consonance with the Department's objectives of competition and 
support of the small business program, award of contracts should not be 
made solely on the basis of ability or willingness to cost-share. Awards 
should be made primarily on the contractor's competence and only after 
adequate competition has been obtained among large and small business 
organizations whenever possible. The offeror's willingness to share 
costs should not be considered in the technical evaluation process but 
as a business consideration, which is secondary to selecting the best 
qualified source.



Sec. 335.071  Special determinations and findings affecting research and 
          development contracting.

    OPDIV heads for health agencies shall sign individual and class 
determinations and findings for:
    (a) Acquisition or construction of equipment or facilities on 
property not owned by the United States pursuant to 42 U.S.C. 241(a)(7); 
and
    (b) Use of an indemnification provision in a research contract 
pursuant to 42 U.S.C. 241(a)(7).

[[Page 66]]



                    SUBCHAPTER G_CONTRACT MANAGEMENT

                    PART 342_CONTRACT ADMINISTRATION

                    Subpart 342.7_Indirect Cost Rates

Sec.

Sec. 342.705  Final indirect cost rates.

                   Subpart 342.70_Contract Monitoring


Sec. 342.7001  Purpose.

Sec. 342.7002  Contract monitoring responsibilities.

Sec. 342.7003  Withholding of contract payments.

Sec. 342.7003-1  Policy.

Sec. 342.7003-2  Procedures.

Sec. 342.7003-3  Withholding payments.

         Subpart 342.71_Administrative Actions for Cost Overruns


Sec. 342.7001   Scope of subpart.

Sec. 342.7101  Contract administration.

Sec. 342.7101-1  General.

Sec. 342.7101-2  Procedures.

Sec. 342.7102  Contract modifications.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4252, Jan. 17, 2001, unless otherwise noted.

                    Subpart 342.7_Indirect Cost Rates



Sec. 342.705  Final indirect cost rates.

    The Director, Division of Cost Allocation of the Program Support 
Center within the servicing HHS regional office has been delegated the 
authority to establish indirect cost rates, research patient care rates, 
and, as necessary, fringe benefit, computer, and other special costing 
rates for use in contracts and grants awarded to State and local 
governments, colleges and universities, hospitals, and other nonprofit 
organizations.

                   Subpart 342.70_Contract Monitoring



Sec. 342.7001   Purpose.

    Contract monitoring is an essential element of contract 
administration and the acquisition process. This subpart describes the 
Department's operating concepts regarding contract monitoring, performed 
jointly by the project officer and the contracting officer, to ensure 
that the required monitoring is performed, timely remedial action is 
taken when necessary, and a determination is made that contract 
objectives have been met.



Sec. 342.7002  Contract monitoring responsibilities.

    (a) Upon execution of the contract, the mutual obligations of the 
Government and the contractor are established by, and limited to, the 
written stipulations in the contract. Unless authorized by the 
contracting officer, HHS personnel shall not direct or request the 
contractor to assume any obligation or take any actions not specifically 
required by the contract. Only the contracting officer may impose a 
requirement which will result in a change to the contract. All contract 
changes must be directed in writing or confirmed in writing by the 
contracting officer.
    (b) The contracting officer is responsible for assuring compliance 
with all terms of the contract, especially the statutory, legal, 
business, and regulatory provisions. Whether or not a postaward 
conference is held, the contracting officer shall inform the contractor 
by letter (if not already stipulated by contract provisions) of the 
authorities and responsibilities of the Government personnel with whom 
the contractor will be dealing throughout the life of the contract.
    (c) The contracting officer must depend on program, technical, and 
other personnel for assistance and advice in monitoring the contractor's 
performance, and in other areas of postaward administration. The 
contracting officer must assure that responsibilities assigned to these 
personnel are understood and carried out. The individual roles and 
corresponding responsibilities typically involve, but are not limited 
to, the following:
    (1) The role of program and technical personnel in monitoring the 
contract to assist or advise the contracting officer (or act as his/her 
representative when so designated by the contracting officer) in 
activities such as:

[[Page 67]]

    (i) Providing technical monitoring during contract performance, and 
issuing letters to the contractor and contracting officer relating to 
delivery, acceptance, or rejection in accordance with the terms of the 
contract;
    (ii) Assessing contractor performance, including inspection and 
testing of products and evaluation of reports and data;
    (iii) Recommending necessary changes to the schedule of work and 
period of performance in order to accomplish the objectives of the 
contract. This shall be accomplished by a written request to the 
contracting officer, together with an appropriate justification and 
funds availability citation;
    (iv) Reviewing invoices/vouchers and recommending approval/
disapproval action by the contracting officer, to include comments 
regarding anything unusual discovered in the review;
    (v) Reviewing and recommending approval or disapproval of 
subcontractors, overtime, travel, and key personnel changes; and
    (vi) Participating, as necessary, in various phases of the contract 
closeout process.
    (2) The role of the project officer in performing required aspects 
of the contract monitoring process. In addition to those applicable 
activities set forth in paragraph (c)(1) of this section, the project 
officer shall:
    (i) Submit periodic reports to the contracting officer that 
concisely explain the status of the contract, and include recommended 
actions for any problems reported. Provide the contracting officer with 
written notification of evaluation and approval/disapproval of contract 
deliverables and of completion of tasks or phases. The contracting 
officer will, in turn, provide the contractor with written notification 
of approval or disapproval unless the responsibility has been delegated 
by the contracting officer, in which case the person responsible for 
such action will notify the contractor and provide a copy to the 
contracting officer for inclusion in the contract file;
    (ii) Monitor the technical aspects of the contractor's business and 
technical progress, identify existing and potential problems that 
threaten performance, and immediately inform the contracting officer of 
deviations from contract objectives, or from any technical or delivery 
requirements, so that remedial measures may be instituted accordingly;
    (iii) Provide immediate notification to the head of the program 
office responsible for the program whenever it is determined that 
program objectives are not being met, together with specific 
recommendations of action to be taken. A copy of the project officer's 
report and recommendation shall be transmitted to the contracting 
officer for appropriate action;
    (iv) Submit, within 120 days after contract completion, a final 
assessment report to the contracting officer. The report should include 
analysis of the contractor's performance, including the contract and 
program objectives achieved and missed. A copy of the final assessment 
report shall be forwarded to the head of the program office responsible 
for the program for management review and follow-up, as necessary; and
    (v) Accompany and/or provide, when requested, technical support to 
the HHS auditor in the conduct of floor checks.
    (3) The role of the contract administrator, auditor, cost analyst, 
and property administrator in assisting or advising the contracting 
officer in postaward administration activities such as:
    (i) Evaluation of contractor systems and procedures, to include 
accounting policies and procedures, purchasing policies and practices, 
property accounting and control, wage and salary plans and rate 
structures, personnel policies and practices, etc.;
    (ii) Processing of disputes under the Disputes clause and any 
resultant appeals;
    (iii) Modification or termination of the contract; and
    (iv) Determination of the allowability of cost charges to incentive 
or cost-reimbursement type contracts and progress payments under fixed-
price contracts. This is especially important when award is made to new 
organizations or those with financial weaknesses.

[[Page 68]]

    (d) The contracting officer is responsible for assuring that 
contractor performance and contract monitoring are carried out in 
conformance with contract provisions. If performance is not satisfactory 
or if problems are anticipated, it is essential that the contracting 
officer take immediate action to protect the Government's rights under 
the contract. The contracting officer shall notify his/her immediate 
supervisor of problems that cannot be resolved within contract 
limitations and whenever contract or program objectives are not met. The 
notification shall include a statement of action being take by the 
contracting officer.



Sec. 342.7003  Withholding of contract payments.



Sec. 342.7003-1  Policy.

    (a) All solicitations and resultant contracts shall contain the 
withholding of contract payments clause at 352.232-9, and an excusable 
delays clause, or a clause which incorporates the definition of 
excusable delays. The excusable delays clause at 352.249-14 shall be 
used when the solicitation and resultant contract (other than purchase 
orders) does not contain a default or other excusable delays clause.
    (b) The transmittal letter used to convey the contract to each 
contractor shall contain a notice which highlights the contractor's 
agreement with the withholding of contract payments clause.
    (c) No contract payment shall be made when any report required to be 
submitted by the contractor is overdue, or the contractor fails to 
perform or deliver work or services as required by the contract.
    (d) The contracting officer shall issue a ten-day cure notice or 
initiate appropriate termination action for any failure in the 
contractor's performance as stated in paragraph (c) of this section.



Sec. 342.7003-2  Procedures.

    (a) The contracting officer is responsible for initiating immediate 
action to protect the Government's rights whenever the contractor fails 
to comply with either the delivery or reporting provisions of the 
contract. Compliance with the reporting provisions includes those 
reports to be submitted directly to the payment office. If such a report 
is not submitted on time, the contracting officer is to be notified 
promptly by the payment officer.
    (b) When the contract contains a termination for default clause, the 
contractor's failure to either submit any required report when due or 
perform or deliver services or work when required by the contract is to 
be considered a default in performance. In either circumstance, the 
contracting officer is to immediately issue a formal ten-day cure notice 
pursuant to the default clause. The cure notice is to follow the format 
prescribed in FAR 49.607 and is to include a statement to the effect 
that contract payments will be withheld if the default is not cured or 
is not determined to be excusable.
    (1) If the default is cured or is determined to be excusable, the 
contracting officer is not to initiate the withholding action.
    (2) If the default is not determined to be excusable or a response 
is not received within the allotted time, the contracting officer is to 
initiate withholding action on all contract payments and is to determine 
whether termination for default or other action would be in the best 
interest of the Government.
    (c) When the contract does not contain a termination for default 
clause, the contractor's failure to either submit any required report 
when due or perform or deliver services or work when required by the 
contract is to be considered a failure to perform. In either 
circumstance, the contracting officer is to immediately issue a written 
notice to the contractor specifying the failure and providing a period 
of ten days, or longer period as determined necessary by the contracting 
officer, in which the contractor is to cure the failure or establish an 
excusable delay. The contracting officer is to include a statement in 
the written notice to the effect that contract payments will be withheld 
if the failure is not cured or is not determined to be excusable.
    (1) If the failure is cured or is determined to be excusable, the 
contracting officer is not to initiate the withholding action.

[[Page 69]]

    (2) If the failure is not determined to be excusable or a response 
is not received within the allotted time, the contracting officer is to 
initiate withholding action on all contract payments and is to determine 
whether termination for convenience or other action would be in the best 
interest of the Government.
    (d) The contracting officer should consult FAR subpart 49.4 for 
further guidance before taking any of the actions described in this 
section.



Sec. 342.7003-3  Withholding payments.

    (a) When making the determination that contract payments should be 
withheld in accordance with the Withholding of Contract Payments clause, 
the contracting officer is to immediately notify the servicing finance 
office in writing of the determination to suspend payments. The notice 
of suspension is to contain all elements of information required by the 
payment office to properly identify the contract and the applicable 
accounts involved.
    (b) The contracting officer is to immediately notify the contractor 
in writing that payments have been suspended until the default or 
failure is cured.
    (c) When the contractor cures the default or failure, the 
contracting officer is to immediately notify, in writing, all recipients 
of the notice of suspension that the suspension is to be lifted and 
contract payments are to be resumed.
    (d) When exercising actions regarding the withholding of payment 
procedures, the contracting officer must be careful not to waive any of 
the Government's rights when corresponding with the contractor or when 
taking any other actions.

         Subpart 342.71_Administrative Actions for Cost Overruns



Sec. 342.7100  Scope of subpart.

    This subpart sets forth the procedures to be followed when a cost 
overrun is anticipated; i.e., the allowable actual cost of performing a 
cost-reimbursement type contract is expected to exceed the total 
estimated cost specified in the contract.



Sec. 342.7101  Contract administration.



Sec. 342.7101-1  General.

    Upon receipt of information that a contractor's accumulated cost and 
projected expenditures will exceed the limit of funds obligated by the 
contract, the contracting officer shall coordinate immediately with the 
appropriate program office to determine whether the contract should be 
modified or terminated. If the contracting officer receives information 
from a source other than the contractor that a cost overrun is 
anticipated, the contracting officer shall verify the information with 
the contractor, and remind the contractor of the notification 
requirements of the Limitation of Cost clause.



Sec. 342.7101-2  Procedures.

    (a) Upon notification that a cost overrun is anticipated, the 
contracting officer shall inform the contractor to submit a request for 
additional funds which is to include:
    (1) Name and address of contractor.
    (2) Contract number and expiration date.
    (3) Contract item(s) and amount(s) creating overrun.
    (4) The elements of cost which changed from the original estimate 
(i.e., labor, material, travel, overhead, etc.) to be furnished in the 
following format:
    (i) Original estimate,
    (ii) Costs incurred to date,
    (iii) Estimated cost to completion,
    (iv) Revised estimate, and
    (v) Amount of adjustment.
    (5) The factors responsible for the increase, i.e., error in 
estimate, changed conditions, etc.
    (6) The latest date by which funds must be available for commitment 
to avoid contract slippage, work stoppage, or other program impairment.
    (b) When the contractor submits a notice of an impending overrun, 
the contracting officer shall:
    (1) Immediately advise the appropriate program office and furnish a 
copy of the notice and any other data received;

[[Page 70]]

    (2) Request audit or cost advisory services, and technical support, 
as necessary, for evaluation of information and data received; and
    (3) Maintain continuous follow-up with the program office to obtain 
a timely decision as to whether the work under the contract should be 
continued and additional funds provided, or the contract terminated. The 
decision of the program office must be supported by an appropriate 
written statement and funding authority, or a formal request for 
termination, when applicable. After a programming and funding decision 
is received from the program office, the contracting officer shall 
promptly notify the contractor in writing that:
    (i) A specified amount of additional funds has been allotted to the 
contract by a contractual instrument; or
    (ii) Work will be discontinued when the funds allotted to the 
contract have been exhausted, and that any work performed after that 
date is at the contractor's risk; or
    (iii) The Government is considering whether additional funds should 
be allotted to the contract and will notify the contractor as soon as 
possible, but that any work performed after the funds then allocated to 
the contract have been exhausted is at the contractor's risk. Timely, 
formal notification of the Government's intention is essential in order 
to preclude loss of contractual rights in the event of dispute, 
termination, or litigation.
    (c) If program requirements permit, contracting officers should 
refrain from issuing any contractual documents which will require new 
work or an extension of time, pending resolution of an overrun or 
additional fund request.



Sec. 342.7102  Contract modifications.

    (a) Modifications to contracts containing the Limitation of Cost 
clause shall include either:
    (1) A provision increasing the estimated or ceiling amount referred 
to in the Limitation of Cost clause of the contract and stating that the 
clause will thereafter apply in respect to the increased amount; or
    (2) A provision stating that the estimated or ceiling amount 
referred to in the contract is not changed by the modification and that 
the Limitation of Cost clause will continue to apply with respect to the 
amount in effect prior to the modification.
    (b) A fixed-fee provided in a contract shall not be changed when 
funding a cost overrun. Changes in fixed-fee will be made only to 
reflect changes in the scope of work which justify an increase or 
decrease in fee.

[[Page 71]]



                     SUBCHAPTER H_CLAUSES AND FORMS

          PART 352_SOLICITATION PROVISIONS AND CONTRACT CLAUSES

              Subpart 352.2_Texts of Provisions and Clauses

Sec.

Sec. 352.202-1  Definitions.

Sec. 352.215-1  Instructions to offerors--Competitive acquisition.

Sec. 352.215-70  Late proposals and revisions.

Sec. 352.216-72  Additional cost principles.

Sec. 352.223-70  Safety and health.

Sec. 352.224-70  Confidentiality of information.

Sec. 352.228-7  Insurance--Liability to third persons.

Sec. 352.232-9  Withholding of contract payments.

Sec. 352.232-74  Estimated cost and fixed fee--Incrementally funded 
          contract.

Sec. 352.232-75  Incremental funding.

Sec. 352.233-70  Litigation and claims.

Sec. 352.242-71  Final decisions on audit findings.

Sec. 352.249-14  Excusable delays.

Sec. 352.270-1  Accessibility of meetings, conferences, and seminars to 
          persons with disabilities.

Sec. 352.270-2  Indian preference.

Sec. 352.270-3  Indian preference program.

Sec. 352.270-4  Pricing of adjustments.

Sec. 352.270-5  Key personnel.

Sec. 352.270-6  Publications and publicity.

Sec. 352.270-7  Paperwork Reduction Act.

Sec. 352.270-8  Protection of human subjects.

Sec. 352.270-9  Care of laboratory animals.

    Authority: 5 U.S.C. 301, 40 U.S.C. 486(c).

    Source: 66 FR 4255, Jan. 17, 2001, unless otherwise noted.

              Subpart 352.2_Texts of Provisions and Clauses



Sec. 352.202-1  Definitions.

    As prescribed in 302.201, the FAR Definitions clause at 52.202-1 is 
to be used as modified:

                         Definitions (Jan. 2001)

    (a) Substitute the following as paragraph (a):
    ``(a) The term ``Secretary'' or ``Head of the Agency'' (also called 
``Agency Head'') means the Secretary, Under Secretary, or any Assistant 
Secretary, Administrator or Commissioner of the Department of Health and 
Human Services; and the term ``his/her duly authorized representative'' 
means any person, persons, or board authorized to act for the 
Secretary.''
    (b) Add the following paragraph (h) or its alternate, as 
appropriate:
    ``(h) The term ``Project Officer'' means the person representing the 
Government for the purpose of technical monitoring of contract 
performance. The Project Officer is not authorized to issue any 
instructions or directions which effect any increases or decreases in 
the scope of work or which would result in the increase or decrease of 
the price of this contract or a change in the delivery dates or 
performance period of this contract.''
        or
    Alternate:
    ``(h) The term ``Project Officer'' means the person representing the 
Government for the purpose of technical monitoring of contract 
performance. The Project Officer is not authorized to issue any 
instructions or directions which effect any increases or decreases in 
the scope of work or which would result in the increase or decrease of 
the cost of this contract or a change in performance period of this 
contract. In addition, the Project Officer is not authorized to receive 
or act upon the Contractor's notification of a revised cost estimate 
pursuant to the Limitation of Cost or Limitation of Funds clause of this 
contract.''



Sec. 352.215-1  Instructions to offerors--Competitive acquisition.

    Insert the following paragraph (e) in place of paragraph (e) of the 
provision at FAR 52.215-1:

    (e) Restriction on disclosure and use of data. (1) The proposal 
submitted in response to this request may contain data (trade secrets; 
business data, e.g., commercial information, financial information, and 
cost and pricing data; and technical data) which the offeror, including 
its prospective subcontractor(s), does not want used or disclosed for 
any purpose other than for evaluation of the proposal. The use and 
disclosure of any data may be so restricted; provided, that the 
Government determines that the data is not required to be disclosed 
under the Freedom of Information Act, 5 U.S.C. 552, as amended, and the 
offeror marks the cover sheet of the proposal with the following legend, 
specifying the particular portions of the proposal which are to be 
restricted in accordance with the conditions of the legend. The 
Government's determination to withhold or disclose a record will be 
based upon the particular circumstances involving the record in question 
and whether the record may be exempted from disclosure under the Freedom 
of Information Act. The legend reads:
    Unless disclosure is required by the Freedom of Information Act, 5 
U.S.C. 552, as

[[Page 72]]

amended, (the Act) as determined by Freedom of Information (FOI) 
officials of the Department of Health and Human Services, data contained 
in the portions of this proposal which have been specifically identified 
by page number, paragraph, etc. by the offeror as containing restricted 
information shall not be used or disclosed except for evaluation 
purposes.
    The offeror acknowledges that the Department may not be able to 
withhold a record (data, document, etc.) nor deny access to a record 
requested pursuant to the Act and that the Department's FOI officials 
must make that determination. The offeror hereby agrees that the 
Government is not liable for disclosure if the Department has determined 
that disclosure is required by the Act.
    If a contract is awarded to the offeror as a result of, or in 
connection with, the submission of this proposal, the Government shall 
have right to use or disclose the data to the extent provided in the 
contract. Proposals not resulting in a contract remain subject to the 
Act.
    The offeror also agrees that the Government is not liable for 
disclosure or use of unmarked data and may use or disclose the data for 
any purpose, including the release of the information pursuant to 
requests under the Act. The data subject to this restriction are 
contained in pages (insert page numbers, paragraph designations, etc. or 
other identification).
    (2) In addition, the offeror should mark each page of data it wishes 
to restrict with the following statement:
    ``Use or disclosure of data contained on this page is subject to the 
restriction on the cover sheet of this proposal or quotation.''
    (3) Offerors are cautioned that proposals submitted with restrictive 
legends or statements differing in substance from the above legend may 
not be considered for award. The Government reserves the right to reject 
any proposal submitted with a nonconforming legend.



Sec. 352.215-70  Late proposals and revisions.

    As prescribed in 315.208, the following provision may be included in 
the solicitation:

                 Late Proposals and Revisions (NOV 1986)

    Notwithstanding the procedures contained in FAR 52.215-1(c)(3) of 
the provision of this solicitation entitled Instructions to Offerors-
Competitive Acquisition, a proposal received after the date specified 
for receipt may be considered if it offers significant cost or technical 
advantages to the Government; and it was received before proposals were 
distributed for evaluation, or within five calendar days after the exact 
time specified for receipt, whichever is earlier.


(End of provision)



Sec. 352.216-72  Additional cost principles.

    As prescribed in 316.307(j), insert the following clause in all 
solicitations and resultant cost-reimbursement contracts:

                  Additional Cost Principles (OCT 1990)

    (a) Bid and proposal costs. (1) Bid and proposal costs are the 
immediate costs of preparing bids, proposals, and applications for 
potential Federal and non-Federal contracts, grants, and agreements, 
including the development of scientific, cost, and other data needed to 
support the bids, proposals, and applications.
    (2) Bid and proposal costs of the current accounting period are 
allowable as indirect costs.
    (3) Bid and proposal costs of past accounting periods are 
unallowable in the current period. However, if the organization's 
established practice is to treat these costs by some other method, they 
may be accepted if they are found to be reasonable and equitable.
    (4) Bid and proposal costs do not include independent research and 
development costs covered by the following paragraph, or preaward costs 
covered by paragraph 38 of Attachment B to OMB Circular A-122.
    (b) Independent research and development costs. (1) Independent 
research and development is research and development conducted by an 
organization which is not sponsored by Federal or non-Federal contracts, 
grants, or other agreements.
    (2) Independent research and development shall be allocated its 
proportionate share of indirect costs on the same basis as the 
allocation of indirect costs to sponsored research and development.
    (3) The cost of independent research and development, including its 
proportionate share of indirect costs, are unallowable.


(End of clause)



Sec. 352.223-70  Safety and health.

    The following clause, or one reading substantially the same, shall 
be used as prescribed in 323.7002:

                      Safety and Health (JAN 2001)

    (a) To help ensure the protection of the life and health of all 
persons, and to help prevent damage to property, the Contractor shall 
comply with all Federal, State and local laws and regulations applicable 
to the work being performed under this contract. These laws are 
implemented and/or enforced by the Environmental Protection Agency, 
Occupational Safety and Health Administration and other agencies at the 
Federal, State and

[[Page 73]]

local levels (Federal, State and local regulatory/enforcement agencies).
    (b) Further, the Contractor shall take or cause to be taken 
additional safety measures as the Contracting Officer, in conjunction 
with the project or other appropriate officers, determines to be 
reasonably necessary. If compliance with these additional safety 
measures results in an increase or decrease in the cost or time required 
for performance of any part of work under this contract, an equitable 
adjustment will be made in accordance with the applicable ``Changes'' 
clause set forth in this contract.
    (c) The Contractor shall maintain an accurate record of, and 
promptly report to the Contracting Officer, all accidents or incidents 
resulting in the exposure of persons to toxic substances, hazardous 
materials or hazardous operations; the injury or death of any person; 
and/or damage to property incidental to work performed under the 
contract and all violations for which the Contractor has been cited by 
any Federal, State or local regulatory/enforcement agency. The report 
shall include a copy of the notice of violation and the findings of any 
inquiry or inspection, and an analysis addressing the impact these 
violations may have on the work remaining to be performed. The report 
shall also state the required action(s), if any, to be taken to correct 
any violation(s) noted by the Federal, State or local regulatory/
enforcement agency and the time frame allowed by the agency to 
accomplish the necessary corrective action.
    (d) If the Contractor fails or refuses to comply with the Federal, 
State or local regulatory/enforcement agency's directive(s) regarding 
any violation(s) and prescribed corrective action(s), the Contracting 
Officer may issue an order stopping all or part of the work until 
satisfactory corrective action (as approved by the Federal, State or 
local regulatory/enforcement agencies) has been taken and documented to 
the Contracting Officer. No part of the time lost due to any stop work 
order shall be subject to a claim for extension of time or costs or 
damages by the Contractor.
    (e) The Contractor shall insert the substance of this clause in each 
subcontract involving toxic substances, hazardous materials, or 
hazardous operations. Compliance with the provisions of this clause by 
subcontractors will be the responsibility of the Contractor.


(End of Clause)



Sec. 352.224-70  Confidentiality of information.

    The following clause is covered by the policy set forth in subpart 
324.70 and is to be used in accordance with the instructions set forth 
in 324.7004.

                Confidentiality of Information (APR 1984)

    (a) Confidential information, as used in this clause, means 
information or data of a personal nature about an individual, or 
proprietary information or data submitted by or pertaining to an 
institution or organization.
    (b) In addition to the types of confidential information described 
in paragraph (a) of this clause, information which might require special 
consideration with regard to the timing of its disclosure may derive 
from studies or research, during which public disclosure of preliminary 
unvalidated findings could create erroneous conclusions which might 
threaten public health or safety if acted upon.
    (c) The Contracting Officer and the Contractor may, by mutual 
consent, identify elsewhere in this contract specific information and/or 
categories of information which the Government will furnish to the 
Contractor or that the Contractor is expected to generate which is 
confidential. Similarly, the Contracting Officer and the Contractor may, 
by mutual consent, identify such confidential information from time to 
time during the performance of the contract. Failure to agree will be 
settled pursuant to the ``Disputes'' clause.
    (d) If it is established elsewhere in this contract that information 
to be utilized under this contract, or a portion thereof, is subject to 
the Privacy Act, the Contractor will follow the rules and procedures of 
disclosure set forth in the Privacy Act of 1974, 5 U.S.C. 552a, and 
implementing regulations and policies, with respect to systems of 
records determined to be subject to the Privacy Act.
    (e) Confidential information, as defined in paragraph (a) of this 
clause, that is information or data of a personal nature about an 
individual, or proprietary information or data submitted by or 
pertaining to an institution or organization, shall not be disclosed 
without the prior written consent of the individual, institution, or 
organization.
    (f) Written advance notice of at least 45 days will be provided to 
the Contracting Officer of the Contractor's intent to release findings 
of studies or research, which have the possibility of adverse effects on 
the public or the Federal agency, as described in paragraph (b) of this 
clause. If the Contracting Officer does not pose any objections in 
writing within the 45-day period, the Contractor may proceed with 
disclosure. Disagreements not resolved by the Contractor and the 
Contracting Officer will be settled pursuant to the ``Disputes'' clause.
    (g) Whenever the Contractor is uncertain with regard to the proper 
handling of material under the contract, or if the material in question 
is subject to the Privacy Act or is confidential information subject to 
the provisions of this clause, the Contractor should

[[Page 74]]

obtain a written determination from the Contracting Officer prior to any 
release, disclosure, dissemination, or publication.
    (h) Contracting Officer determinations will reflect the result of 
internal coordination with appropriate program and legal officials.
    (i) The provisions of paragraph (e) of this clause shall not apply 
when the information is subject to conflicting or overlapping provisions 
in other Federal, State or local laws.


(End of clause)



Sec. 352.228-7  Insurance--Liability to third persons.

    As prescribed in 328.311-2, contracting officers shall include the 
following clause in all cost-reimbursement contracts, in lieu of the 
clause at FAR 52.228-7:

            Insurance--Liability to Third Persons (DEC 1991)

    (a)(1) Except as provided in paragraph (a)(2) immediately following, 
or in paragraph (h) of this clause (if the clause has a paragraph (h)), 
the Contractor shall provide and maintain workers' compensation, 
employer's liability, comprehensive general liability (bodily injury), 
comprehensive automobile liability (bodily injury and property damage) 
insurance, and such other insurance as the Contracting Officer may 
require under this contract.
    (2) The Contractor may, with the approval of the Contracting 
Officer, maintain a self-insurance program; provided that, with respect 
to workers' compensation, the Contractor is qualified pursuant to 
statutory authority.
    (3) All insurance required by this paragraph shall be in form and 
amount and for those periods as the Contracting Officer may require or 
approve and with insurers approved by the Contracting Officer.
    (b) The Contractor agrees to submit for the Contracting Officer's 
approval, to the extent and in the manner required by the Contracting 
Officer, any other insurance that is maintained by the Contractor in 
connection with performance of this contract and for which the 
Contractor seeks reimbursement.
    (c) Except as provided in paragraph (h) of this clause (if the 
clause has a paragraph (h)), the Contractor shall be reimbursed:
    (1) For that portion of the reasonable cost of insurance allocable 
to this contract, and required or approved under this clause; and
    (2) For certain liabilities (and expenses incidental to such 
liabilities) to third persons not compensated by insurance or otherwise 
within the funds available under the Limitation of Cost or the 
Limitation of Funds clause of this contract. These liabilities must 
arise out of the performance of this contract, whether or not caused by 
the negligence of the Contractor or the Contractor's agents, servants, 
or employees, and must be represented by final judgments or settlements 
approved in writing by the Government. These liabilities are for:
    (i) Loss of or damage to property (other than property owned, 
occupied, or used by the Contractor, rented to the Contractor, or in the 
care, custody, or control of the Contractor); or
    (ii) Death or bodily injury.
    (d) The Government's liability under paragraph (c) of this clause is 
limited to the amounts reflected in final judgements, or settlements 
approved in writing by the Government, but in no event to exceed the 
funds available under the Limitation of Cost or Limitation of Funds 
clause of this contract. Nothing in this contract shall be construed as 
implying that, at a later date, the Government will request, or the 
Congress will appropriate, funds sufficient to meet any deficiencies.
    (e) The Contractor shall not be reimbursed for liabilities (and 
expenses incidental to such liabilities):
    (1) For which the Contractor is otherwise responsible under the 
express terms of any clause specified in the Schedule or elsewhere in 
the contract:
    (2) For which the Contractor has failed to insure or to maintain 
insurance as required by the Contracting Officer; or
    (3) That result from willful misconduct or lack of good faith on the 
part of the Contractor's directors, officers, managers, superintendents, 
or other representatives who have supervision or direction of:
    (i) All or substantially all of the Contractor's business;
    (ii) All or substantially all of the Contractor's operations at any 
one plant or separate location in which this contract is being 
performed; or
    (iii) A separate and complete major industrial operation in 
connection with the performance of this contract.
    (f) The provisions of paragraph (e) of this clause shall not 
restrict the right of the Contractor to be reimbursed for the cost of 
insurance maintained by the Contractor in connection with the 
performance of this contract, other than insurance required in 
accordance with this clause; provided, that such cost is allowable under 
the Allowable Cost and Payment clause of this contract.
    (g) If any suit or action is filed or any claim is made against the 
Contractor, the cost and expense of which may be reimbursable to the 
Contractor under this contract, and the risk of which is then uninsured 
or is insured for less than the amount claimed, the Contractor shall:
    (1) Immediately notify the Contracting Officer and promptly furnish 
copies of all pertinent papers received;

[[Page 75]]

    (2) Authorize Government representatives to collaborate with counsel 
for the insurance carrier in settling or defending the claim when the 
amount of the liability claimed exceeds the amount of coverage; and
    (3) Authorize Government representatives to settle or defend the 
claim and to represent the Contractor in or to take charge of any 
litigation, if required by the Government, when the liability is not 
insured or covered by the bond. The Contractor may, at its own expense, 
be associated with the Government representatives in any such claim or 
litigation.

(End of clause)

    Alternate I (APR 1984). If the successful offeror represents in the 
offer that the offeror is partially immune from tort liability as a 
State agency, add the following paragraph (h) to the basic clause:
    (h) Notwithstanding paragraphs (a) and (c) of this clause--
    (1) The Government does not assume any liability to third persons, 
nor will the Government reimburse the Contractor for its liability to 
third persons, with respect to loss due to death, bodily injury, or 
damage to property resulting in any way from the performance of this 
contract or any subcontract under this contract; and
    (2) The Contractor need not provide or maintain insurance coverage 
as required by paragraph (a) of this clause; provided, that the 
Contractor may obtain any insurance coverage deemed necessary, subject 
to approval by the Contracting Officer as to form, amount, and duration. 
The Contractor shall be reimbursed for the cost of such insurance and, 
to the extent provided in paragraph (c) of this clause, to liabilities 
to third persons for which the Contractor has obtained insurance 
coverage as provided in this paragraph, but for which such coverage is 
insufficient in amount.

(End of clause)

    Alternate II (APR 1984). If the successful offeror represents in the 
offer that the offeror is totally immune from tort liability as a State 
agency, substitute the following paragraphs (a) and (b) for paragraphs 
(a) and (b) of the basic clause:
    (a) The Government does not assume any liability to third persons, 
nor will the Government reimburse the Contractor for its liability to 
third persons, with respect to loss due to death, bodily injury, or 
damage to property resulting in any way from the performance of this 
contract or any subcontract under this contract.
    (b) If any suit or action is filed, or if any claim is made against 
the Contractor, the cost and expense of which may be reimbursable to the 
Contractor under this contract, the Contractor shall immediately notify 
the Contracting Officer and promptly furnish copies of all pertinent 
papers received by the Contractor. The Contractor shall, if required by 
the Government, authorize Government representatives to settle or defend 
the claim and to represent the Contractor in or take charge of any 
litigation. The Contractor may, at its own expense, be associated with 
the Government representatives in any such claims or litigation


(End of clause)



Sec. 352.232-9  Withholding of contract payments.

    Insert the following clause in all solicitations and contracts other 
than purchase orders:

               Withholding of Contract Payments (APR 1984)

    Notwithstanding any other payment provisions of this contract, 
failure of the Contractor to submit required reports when due or failure 
to perform or deliver required work, supplies, or services, will result 
in the withholding of payments under this contract unless such failure 
arises out of causes beyond the control, and without the fault or 
negligence of the Contractor as defined by the clause entitled 
``Excusable Delays'' or ``Default'', as applicable. The Government shall 
promptly notify the Contractor of its intention to withhold payment of 
any invoice or voucher submitted.


(End of clause)



Sec. 352.232-74  Estimated cost and fixed fee--Incrementally funded 
          contract.

    The following clause, or one reading substantially as it, shall be 
included in the Special Provisions of an incrementally funded contract:

          Consideration-Estimated Cost and Fixed Fee (APR 1984)

    (a) It is estimated that the total cost to the Government for full 
performance of this contract will be $___, of which the sum of $___ 
represents the estimated reimbursable costs and $___ represents the 
fixed-fee.
    (b) Total funds currently available for payment and allotted to this 
contract are $___, of which $___ represents the estimated reimbursable 
costs and $___ represents the fixed-fee. For further provisions on 
funding, see the Limitation of Funds clause.
    (c) It is estimated that the amount currently allotted will cover 
performance of Phase I which is scheduled to be completed by (date)___.

[[Page 76]]

    (d) The Contracting Officer may allot additional funds to the 
contract without the concurrence of the Contractor.


(End of clause)



Sec. 352.232-75  Incremental funding.

    The following provision shall be included in all requests for 
proposals whenever the use of incremental funding is contemplated:

                     Incremental Funding (JAN 2001)

    (a) It is the Government's intention to negotiate and award a 
contract using the incremental funding concepts described in the clause 
entitled Limitation of Funds. Under the clause, which will be included 
in the resultant contract, initial funds will be obligated under the 
contract to cover the first year of performance. Additional funds are 
intended to be allotted to the contract by contract modification, up to 
and including the full estimated cost of the contract, to accomplish the 
entire project. While it is the Government's intention to progressively 
fund this contract over the entire period of performance up to and 
including the full estimated cost, the Government will not be obligated 
to reimburse the Contractor for costs incurred in excess of the periodic 
allotments, nor will the Contractor be obligated to perform in excess of 
the amount allotted.
    (b) The Limitation of Funds clause to be included in the resultant 
contract shall supersede the Limitation of Cost clause found in the 
General Provisions.


(End of provision)



Sec. 352.233-70  Litigation and claims.

    Insert the following clause in all solicitations and resultant cost-
reimbursement contracts:

                    Litigation and Claims (APR 1984)

    The Contractor shall give the Contracting Officer immediate notice 
in writing of any action, including any proceeding before an 
administrative agency, filed against the Contractor arising out of the 
performance of this contract, including, but not limited to the 
performance of any subcontract hereunder; and any claim against the 
Contractor the cost and expense of which is allowable under the clause 
entitled ``Allowable Cost and Payment.'' Except as otherwise directed by 
the Contracting Officer, the Contractor shall furnish immediately to the 
Contracting Officer copies of all pertinent papers received by the 
Contractor with respect to such action or claim. To the extent not in 
conflict with any applicable policy of insurance, the Contractor may, 
with the Contracting Officer's approval, settle any such action or 
claim. If required by the Contracting Officer, the Contractor shall 
effect an assignment and subrogation in favor of the Government of all 
the Contractor's rights and claims (except those against the Government) 
arising out of any such action or claim against the Contractor; and 
authorize representatives of the Government to settle or defend any such 
action or claim and to represent the Contractor in, or to take charge 
of, any action. If the settlement or defense of an action or claim is 
undertaken by the Government, the Contractor shall furnish all 
reasonable assistance in effecting a settlement or asserting a defense. 
Where an action against the Contractor is not covered by a policy of 
insurance, the Contractor shall, with the approval of the Contracting 
Officer, proceed with the defense of the action in good faith. The 
Government shall not be liable for the expense of defending any action 
or for any costs resulting from the loss thereof to the extent that the 
Contractor would have been compensated by insurance which was required 
by law or regulation or by written direction of the Contracting Officer, 
but which the Contractor failed to secure through its own fault or 
negligence. In any event, unless otherwise expressly provided in this 
contract, the Contractor shall not be reimbursed or indemnified by the 
Government for any liability loss, cost or expense, which the Contractor 
may incur or be subject to by reason of any loss, injury or damage, to 
the person or to real or personal property of any third parties as may 
accrue during, or arise from, the performance of this contract.


(End of clause)



Sec. 352.242-71  Final decisions on audit findings.

    Insert the following clause in all solicitations and resultant cost-
reimbursement contracts.

              Final Decisions on Audit Findings (APR 1984)

    For the purpose of issuing final decisions under the Disputes clause 
of this contract concerning monetary audit findings, the Contracting 
Officer shall be that person with ultimate responsibility for making 
that decision in accordance with Chapter 1-105, Resolution of Audit 
Findings, of the Department's Grants Administration Manual.


(End of clause)



Sec. 352.249-14  Excusable delays.

    Insert the following clause in all solicitations and resultant 
contracts other than purchase orders which do not have either a default 
or excusable

[[Page 77]]

delays clause, as prescribed in 342.7003-1(a):

                       Excusable Delays (APR 1984)

    (a) Except with respect to failures of subcontractors, the 
Contractor shall not be considered to have failed in performance of this 
contract if such failure arises out of causes beyond the control and 
without the fault or negligence of the Contractor.
    (b) Such causes may include, but are not restricted to, acts of God 
or of the public enemy, acts of the Government in either its sovereign 
or contractual capacity, fires, floods, epidemics, quarantine 
restrictions, strikes, freight embargoes, and unusually severe weather, 
but in every case the failure to perform must be beyond the control and 
without the fault or negligence of the Contractor. If the failure to 
perform is caused by the failure of a subcontractor to perform, and if 
such failure arises out of causes beyond the control of both the 
Contractor and subcontractor, and without the fault or negligence of 
either of them, the Contractor shall not be deemed to have failed in 
performance of the contract, unless: the supplies or services to be 
furnished by the subcontractor were obtainable from other sources, the 
Contracting Officer shall have ordered the Contractor in writing to 
procure such supplies or services from such other sources, and the 
Contractor shall have failed to comply reasonably with such order. Upon 
request of the Contractor, the Contracting officer shall ascertain the 
facts and extent of such failure and, if he/she shall determine that any 
failure to perform was occasioned by any one or more of the said causes, 
the delivery schedule shall be revised accordingly, subject to the 
rights of the Government under the termination clause hereof. (As used 
in this clause, the terms ``subcontractor'' and ``subcontractors'' mean 
subcontractor(s) at any tier.)


(End of clause)



Sec. 352.270-1  Accessibility of meetings, conferences, and seminars to 
          persons with disabilities.

    The following clause is to be used in accordance with 370.102:

  Accessibility of Meetings, Conferences, and Seminars to Persons with 
                         Disabilities (JAN 2001)

    The Contractor agrees as follows:
    (a) Planning. The Contractor will develop a plan to assure that any 
meeting, conference, or seminar held pursuant to this contract will meet 
or exceed the minimum accessibility standards set forth in 28 CFR 
36.101-36.500 and Appendix A: ADA Accessibility Guidelines (ADAAG). The 
plan shall be submitted to the project officer for approval prior to 
initiating action. ( A consolidated or master plan for contracts 
requiring numerous meetings, conferences, or seminars may be submitted 
in lieu of separate plans.)
    (b) Facilities. Any facility to be utilized for meetings, 
conferences, or seminars in performance of this contract shall be in 
compliance with 28 CFR 36.101-36.500 and Appendix A. The Contractor 
shall determine, by an on-site inspection, that the facility meets these 
requirements.
    (1) Parking. Parking shall be in compliance with 28 CFR 36.101-
36.500 and Appendix A.
    (2) Entrances. Entrances shall be in compliance with 28 CFR 36.101-
36.500 and Appendix A.
    (3) Meeting Rooms. Meeting rooms, including seating arrangements, 
shall be in compliance with 28 CFR 36.101-36.500 and Appendix A. In 
addition, stages, speaker platforms, etc. which are to be used by 
persons in wheelchairs must be accessible by ramps or lifts. When used, 
the ramp may not necessarily be independently negotiable if space does 
not permit. However, any slope over 1:12 must be approved by the Project 
Officer and the Contractor must provide assistance to negotiate access 
to the stage or platform.
    (4) Restrooms. Restrooms shall be in compliance with 28 CFR 36.101-
36.500 and Appendix A.
    (5) Eating Facilities. Eating facilities in the meeting facility 
must also comply with 28 CFR 36.101-36.500 and Appendix A.
    (6) Overnight Facilities. If overnight accommodations are required, 
the facility providing the overnight accommodations shall also comply 
with 28 CFR 36.101-36.500 and Appendix A.
    (7) Water Fountains. Water fountains shall comply with 28 CFR 
36.101-36.500 and Appendix A.
    (8) Telephones. Public telephones shall comply with 28 CFR 36.101-
36.500 and Appendix A.
    (c) Provisions of Services for Attendees with Sensory Impairments.
    (1) The Contractor, in planning the meeting, conference, or seminar, 
shall include in all announcements and other materials pertaining to the 
meeting, conference, or seminar a notice indicating that services will 
be made available to persons with sensory impairments attending the 
meeting, if requested within five (5) days of the date of the meeting, 
conference, or seminar. The announcement(s) and other material(s) shall 
indicate that persons with sensory impairments may contact a specific 
person(s), at a specific address and phone number(s), to make their 
service requirements known. The phone number(s) shall include a 
telecommunication device for the deaf (TDD).
    (2) The Contractor shall provide, at no additional cost to the 
individual, those services

[[Page 78]]

required by persons with sensory impairments to insure their complete 
participation in the meeting, conference, or seminar.
    (3) As a minimum, when requested in advance, the Contractor shall 
provide the following services:
    (i) For persons with hearing impairments, qualified interpreters. 
Also, the meeting rooms will be adequately illuminated so signing by 
interpreters can be easily seen.
    (ii) For persons with vision impairments, readers and/or cassette 
materials, as necessary, to enable full participation. Also, meeting 
rooms will be adequately illuminated.
    (iii) Agenda and other conference material(s) shall be translated 
into a usable form for persons with sensory impairments. Readers, 
braille translations, large print text, and/or tape recordings are all 
acceptable. These materials shall be available to individuals with 
sensory impairments upon their arrival.
    (4) The Contractor is responsible for making a reasonable effort to 
ascertain the number of individuals with sensory impairments who plan to 
attend the meeting, conference, or seminar. However, if it can be 
determined that there will be no person with sensory impairment in 
attendance, the provision of those services under paragraph (c) of this 
clause for the nonrepresented group, or groups, is not required.


(End of clause)



Sec. 352.270-2  Indian preference.

    The following clause shall be used as prescribed in 370.202(a):

                      Indian Preference (APR 1984)

    (a) The Contractor agrees to give preference in employment 
opportunities under this contract to Indians who can perform required 
work, regardless of age (subject to existing laws and regulations), sex, 
religion, or tribal affiliation. To the extent feasible and consistent 
with the efficient performance of this contract, the Contractor further 
agrees to give preference in employment and training opportunities under 
this contract to Indians who are not fully qualified to perform 
regardless of age (subject to existing laws and regulations), sex, 
religion, or tribal affiliation. The Contractor also agrees to give 
preference to Indian organizations and Indian-owned economic enterprises 
in the awarding of any subcontracts to the extent feasible and 
consistent with the efficient performance of this contract. The 
Contractor shall maintain statistical records as are necessary to 
indicate compliance with this paragraph.
    (b) In connection with the Indian employment preference requirements 
of this clause, the Contractor shall provide opportunities for training 
incident to such employment. Such training shall include on-the-job, 
classroom or apprenticeship training which is designed to increase the 
vocational effectiveness of an Indian employee.
    (c) If the Contractor is unable to fill its employment and training 
opportunities after giving full consideration to Indians as required by 
this clause, those needs may be satisfied by selection of persons other 
than Indians in accordance with the clause of this contract entitled 
``Equal Opportunity.''
    (d) If no Indian organizations or Indian-owned economic enterprises 
are available under reasonable terms and conditions, including price, 
for awarding of subcontracts in connection with the work performed under 
this contract, the Contractor agrees to comply with the provisions of 
this contract involving utilization of small business concerns, small 
disadvantaged business concerns, and women-owned small business 
concerns.
    (e) As used in this clause:
    (1) ``Indian'' means a person who is a member of an Indian Tribe. If 
the Contractor has reason to doubt that a person seeking employment 
preference is an Indian, the Contractor shall grant the preference but 
shall require the individual to provide evidence within thirty (30) days 
from the Tribe concerned that the person is a member of the Tribe.
    (2) ``Indian Tribe'' means an Indian Tribe, pueblo, band, nation, or 
other organized group or community, including Alaska Native village or 
regional or village corporation as defined in or established pursuant to 
the Alaska Native Claims Settlement Act (85 Stat. 688; 43 U.S.C. 1601) 
which is recognized as eligible for the special programs and services 
provided by the United States to Indians because of their status as 
Indians.
    (3) ``Indian organization'' means the governing body of any Indian 
Tribe or entity established or recognized by such governing body in 
accordance with the Indian Financing Act of 1974 (88 Stat. 77; 25 U.S.C. 
1451); and
    (4) ``Indian-owned economic enterprise'' means any Indian-owned 
commercial, industrial, or business activity established or organized 
for the purpose of profit, provided that such Indian ownership shall 
constitute not less than 51 percent of the enterprise, and that 
ownership shall encompass active operation and control of the 
enterprise.
    (f) The Contractor agrees to include the provisions of this clause, 
including this paragraph (f) of this clause, in each subcontract awarded 
at any tier under this contract.
    (g) In the event of noncompliance with this clause, the Contracting 
Officer may terminate the contract in whole or in part or may impose any 
other sanctions authorized by law or by other provisions of the 
contract.


[[Page 79]]



(End of clause)



Sec. 352.270-3  Indian preference program.

    The following clause shall be used as prescribed in 370.202(b):

                  Indian Preference Program (APR 1984)

    (a) In addition to the requirements of the clause of this contract 
entitled ``Indian Preference,'' the Contractor agrees to establish and 
conduct an Indian preference program which will expand opportunities for 
Indians to receive preference for employment and training in connection 
with the work to be performed under this contract, and which will expand 
the opportunities for Indian organizations and Indian-owned economic 
enterprises to receive a preference in the awarding of subcontracts. In 
this connection, the Contractor shall:
    (1) Designate a liaison officer who will maintain liaison with the 
Government and the Tribe(s) on Indian preference matters; supervise 
compliance with the provisions of this clause; and administer the 
Contractor's Indian preference program.
    (2) Advise its recruitment sources in writing and include a 
statement in all advertisements for employment that Indian applicants 
will be given preference in employment and training incident to such 
employment.
    (3) Not more than twenty (20) calendar days after award of the 
contract, post a written notice in the Tribal office of any reservations 
on which or near where the work under this contract is to be performed 
that sets forth the Contractor's employment needs and related training 
opportunities. The notice shall include the approximate numbers and 
types of employees needed; the approximate dates of employment; the 
experience or special skills required for employment, if any; training 
opportunities available; and other pertinent information necessary to 
advise prospective employees of any other employment requirements. The 
Contractor shall also request the Tribe(s) on or near whose 
reservation(s) the work is to be performed to provide assistance to the 
Contractor in filling its employment needs and training opportunities. 
The Contracting Officer will advise the Contractor of the name, 
location, and phone number of the Tribal officials to contact in regard 
to the posting of notices and requests for Tribal assistance.
    (4) Establish and conduct a subcontracting program which gives 
preference to Indian organizations and Indian-owned economic enterprises 
as subcontractors and suppliers under this contract. The Contractor 
shall give public notice of existing subcontracting opportunities and, 
to the extent feasible and consistent with the efficient performance of 
this contract, shall solicit bids or proposals only from Indian 
organizations or Indian-owned economic enterprises. The Contractor shall 
request assistance and information on Indian firms qualified as 
suppliers or subcontractors from the Tribe(s) on or near whose 
reservation(s) the work under the contract is to be performed. The 
Contracting Officer will advise the Contractor of the name, location, 
and phone number of the Tribal officials to be contacted in regard to 
the request for assistance and information. Public notices and 
solicitations for existing subcontracting opportunities shall provide an 
equitable opportunity for Indian firms to submit bids or proposals by 
including: A clear description of the supplies or services required, 
including quantities, specifications, and delivery schedules which 
facilitate the participation of Indian firms; A statement indicating 
that preference will be given to Indian organizations and Indian-owned 
economic enterprises in accordance with section 7(b) of Public Law 93-
638 (88 Stat. 2205; 25 U.S.C. 450e(b)); Definitions for the terms 
``Indian organization'' and ``Indian-owned economic enterprise'' as 
prescribed under the ``Indian Preference'' clause of this contract; A 
statement to be completed by the bidder or offeror that it is an Indian 
organization or Indian-owned economic enterprise; and A closing date for 
receipt of bids or proposals which provides sufficient time for 
preparation and submission of a bid or proposal. If after soliciting 
bids or proposals from Indian organizations and Indian-owned economic 
enterprises, no responsive bid or acceptable proposal is received, the 
Contractor shall comply with the requirements of paragraph (d) of the 
``Indian Preference'' clause of this contract. If one or more 
responsible bids or acceptable proposals are received, award shall be 
made to the low responsible bidder or acceptable offeror if the price is 
determined to be reasonable. If the low responsive bid or acceptable 
proposal is determined to be unreasonable as to price, the Contractor 
shall attempt to negotiate a reasonable price and award a subcontract. 
If a reasonable price cannot be agreed upon, the Contractor shall comply 
with the requirements of paragraph (d) of the ``Indian Preference'' 
clause of this contract.
    (5) Maintain written records under this contract which indicate: The 
numbers of Indians seeking employment for each employment position 
available under this contract; The number and types of positions filled 
by Indians and non-Indians, and the total number of Indians employed 
under this contract; For those positions where there are both Indian and 
non-Indian applicants, and a non-Indian is selected for employment, the 
reason(s) why the Indian applicant was not selected; Actions taken to 
give preference to Indian organizations and Indian-owned economic 
enterprises for subcontracting opportunities which exist under this 
contract;

[[Page 80]]

Reasons why preference was not given to Indian firms as subcontractors 
or suppliers for each requirement where it was determined by the 
Contractor that such preference would not be consistent with the 
efficient performance of the contract; and The number of Indian 
organizations and Indian-owned economic enterprises contacted, and the 
number receiving subcontract awards under this contract.
    (6) Submit to the Contracting Officer for approval a quarterly 
report which summarizes the Contractor's Indian preference program and 
indicates the number and types of available positions filled by Indians 
and non-Indians, and the dollar amounts of all subcontracts awarded to 
Indian organizations and Indian-owned economic enterprises, and to all 
other firms.
    (7) Maintain records pursuant to this clause and keep them available 
for review by the Government until expiration of one (1) year after 
final payment under this contract, or for such longer period as may be 
required by any other clause of this contract or by applicable law or 
regulation.
    (b) For purposes of this clause, the following definitions of terms 
shall apply:
    (1) The terms ``Indian,'' ``Indian Tribe,'' ``Indian Organization,'' 
and ``Indian-owned economic enterprise'' are defined in the clause of 
this contract entitled ``Indian Preference.''
    (2) ``Indian reservation'' includes Indian reservations, public 
domain Indian Allotments, former Indian reservations in Oklahoma, and 
land held by incorporated Native groups, regional corporations, and 
village corporations under the provisions of the Alaska Native Claims 
Settlement Act (85 Stat. 688; 43 U.S.C. 1601 et seq.)
    (3) ``On or near an Indian Reservation'' means on a reservation or 
reservations or within that area surrounding an Indian reservation(s) 
where a person seeking employment could reasonably be expected to 
commute to and from in the course of a work day.
    (c) Nothing in the requirements of this clause shall be interpreted 
to preclude Indian Tribes from independently developing and enforcing 
their own Indian preference requirements. Such requirements must not 
conflict with any Federal statutory or regulatory requirement dealing 
with the award and administration of contracts.
    (d) The Contractor agrees to include the provisions of this clause, 
including this paragraph (d), in each subcontract awarded at any tier 
under this contract and to notify the Contracting Officer of such 
subcontracts.
    (e) In the event of noncompliance with this clause, the Contracting 
Officer may terminate the contract in whole or in part or may impose any 
other sanctions authorized by law or by other provisions of the 
contract.


(End of clause)



Sec. 352.270-4  Pricing of adjustments.

    Insert the following clause in all solicitations and resultant 
fixed-priced contracts other than purchase orders.

                    Pricing of Adjustments (JAN 2001)

    When costs are a factor in determination of a contract price 
adjustment pursuant to the ``Changes'' clause or any provision of this 
contract, such costs shall be determined in accordance with the 
applicable cost principles and procedures set forth below:

------------------------------------------------------------------------
                Principles                     Types of organizations
------------------------------------------------------------------------
(a) Subpart 31.2 of the Federal             Commercial.
 Acquisition Regulation.
(b) Subpart 31.3 of the Federal             Educational.
 Acquisition Regulation.
(c) Subpart 31.6 of the Federal             State, local, and federally
 Acquisition Regulation.                     recognized Indian tribal
                                             governments.
(d) 45 CFR Part 74 Appendix E.............  Hospitals (permforming
                                             research and development
                                             contracts only.
(e) Subpart 31.7 of the Federal             Other nonprofit
 Acquisition Regulation.                     institutions.
------------------------------------------------------------------------



(End of clause)



Sec. 352.270-5  Key personnel.

    Insert the following clause in all solicitations and resultant cost-
reimbursement contracts.

                        Key Personnel (APR 1984)

    The personnel specified in this contract are considered to be 
essential to the work being performed hereunder. Prior to diverting any 
of the specified individuals to other programs, the Contractor shall 
notify the Contracting Officer reasonably in advance and shall submit 
justification (including proposed substitutions) in sufficient detail to 
permit evaluation of the impact on the program. No diversion shall be 
made by the Contractor without the written consent of the Contracting 
Officer; provided, that the Contracting Officer may ratify in writing 
such diversion and such ratification shall constitute the consent of the 
Contracting Officer required by this clause. The contract may be 
modified from time to time during the course of the contract to either 
add or delete personnel, as appropriate.


(End of clause)



Sec. 352.270-6  Publications and publicity.

    Insert the following clause in all solicitations and resultant 
contracts.


[[Page 81]]



                  Publications and Publicity (JUL 1991)

    (a) Unless otherwise specified in this contract, the Contractor is 
encouraged to publish the results of its work under this contract. A 
copy of each article submitted by the Contractor for publication shall 
be promptly sent to the Project Officer. The Contractor shall also 
inform the Project Officer when the article or other publication is 
published, and furnish a copy of it as finally published.
    (b) The Contractor shall include in any publication resulting from 
work performed under this contract a disclaimer reading as follows:
    The content of this publication does not necessarily reflect the 
views or policies of the Department of Health and Human Services, nor 
does mention of trade names, commercial products, or organizations imply 
endorsement by the U.S. Government.''


(End of clause)



Sec. 352.270-7  Paperwork Reduction Act.

    Insert the following clause in all solicitations and contracts.

                   Paperwork Reduction Act (JAN 2001)

    (a) In the event that it subsequently becomes a contractual 
requirement to collect or record information calling either for answers 
to identical questions from 10 or more persons other than Federal 
employees, or information from Federal employees which is outside the 
scope of their employment, for use by the Federal government or 
disclosure to third parties, the Paperwork Reduction Act of 1995 (Pub. 
L. 104-13) shall apply to this contract. No plan, questionnaire, 
interview guide or other similar device for collecting information 
(whether repetitive or single-time) may be used without first obtaining 
clearance from the Office of Management and Budget (OMB). Contractors 
and Project Officers should be guided by the provisions of 5 CFR Part 
1320, Controlling Paperwork Burdens on the Public, and seek the advice 
of the HHS operating division or Office of the Secretary Reports 
Clearance Officer to determine the procedures for acquiring OMB 
clearance.
    (b) The Contractor shall obtain the required OMB clearance through 
the Project Officer before expending any funds or making public 
contracts for the collection of data. The authority to expend funds and 
proceed with the collection of information shall be in writing by the 
Contracting Officer. The Contractor must plan at least 120 days for OMB 
clearance. Excessive delays caused by the Government which arises out of 
causes beyond the control and without the fault or negligence of the 
Contractor will be considered in accordance with the Excusable Delays or 
Default clause of this contract


(End of clause)



Sec. 352.270-8  Protection of human subjects.

    (a) The following provision shall be included in solicitations 
expected to involve human subjects:

  Notice to Offerors of Requirements of 45 CFR Part 46, Protection of 
                        Human Subjects (JAN 2001)

    (a) Copies of the Department of Health and Human Services 
(Department) regulations for the protection of human subjects, 45 CFR 
Part 46, are available from the Office for Protection from Research 
Risks (OPRR), National Institutes of Health, Bethesda, Maryland 20892. 
The regulations provide a systematic means, based on established ethical 
principles, to safeguard the rights and welfare of individuals who 
participate as subjects in research activities supported or conducted by 
the Department.
    (b) The regulations define a human subject as a living individual 
about whom an investigator (whether professional or student) conducting 
research obtains data through intervention or interaction with the 
individual, or identifiable private information. The regulations extend 
to the use of human organs, tissue, and body fluids from individually 
identifiable human subjects as well as to graphic, written, or recorded 
information derived from individually identifiable human subjects. The 
use of autopsy materials is governed by applicable State and local law 
and is not directly regulated by 45 CFR Part 46.
    (c) Activities in which the only involvement of human subjects will 
be in one or more of the categories set forth in 45 CFR 46.101(b)(1-6) 
are exempt from coverage.
    (d) Inappropriate designations of the noninvolvement of human 
subjects or of exempt categories of research in a project may result in 
delays in the review of a proposal. The National Institutes of Health 
will make a final determination of whether the proposed activities are 
covered by the regulations or are in an exempt category, based on the 
information provided in the proposal. In doubtful cases, prior 
consultation with OPRR, (telephone: 301-496-7014), is recommended.
    (e) In accordance with 45 CFR Part 46, prospective Contractors being 
considered for award shall be required to file with OPRR an acceptable 
Assurance of Compliance with the regulations, specifying review 
procedures

[[Page 82]]

and assigning responsibilities for the protection of human subjects. The 
initial and continuing review of a research project by an institutional 
review board shall assure that the rights and welfare of the human 
subjects involved are adequately protected, that the risks to the 
subjects are reasonable in relation to the potential benefits, if any, 
to the subjects and the importance of the knowledge to be gained, and 
that informed consent will be obtained by methods that are adequate and 
appropriate. Prospective Contractors proposing research that involves 
human subjects shall be contacted by OPRR and given detailed 
instructions for establishing an institutional review board and filing 
an Assurance of Compliance.
    (f) It is recommended that OPRR be consulted for advice or guidance 
concerning either regulatory requirements or ethical issues pertaining 
to research involving human subjects.


(End of provision)

    (b) The following clause shall be included in solicitations and 
resultant contracts involving human subjects:

                 Protection of Human Subjects (JAN 2001)

    (a) The Contractor agrees that the rights and welfare of human 
subjects involved in research under this contract shall be protected in 
accordance with 45 CFR Part 46 and with the Contractor's current 
Assurance of Compliance on file with the Office for Protection from 
Research Risks (OPRR), National Institutes of Health (NIH). The 
Contractor further agrees to provide certification at least annually 
that the Institutional Review Board has reviewed and approved the 
procedures, which involve human subjects in accordance with 45 CFR Part 
46 and the Assurance of Compliance.
    (b) The Contractor shall bear full responsibility for the 
performance of all work and services involving the use of human subjects 
under this contract in a proper manner and as safely as is feasible. The 
parties hereto agree that the Contractor retains the right to control 
and direct the performance of all work under this contract. Nothing in 
this contract shall be deemed to constitute the Contractor or any 
subcontractor, agent or employee of the Contractor, or any other person, 
organization, institution, or group of any kind whatsoever, as the agent 
or employee of the Government. The Contractor agrees that it has entered 
into this contract and will discharge its obligations, duties, and 
undertakings and the work pursuant thereto, whether requiring 
professional judgement or otherwise, as an independent contractor 
without imputing liability on the part of the Government for the acts of 
the Contractor or its employees.
    (c) If at any time during the performance of this contract, the 
Contracting officer determines, in consultation with the OPRR, NIH, that 
the Contractor is not in compliance with any of the requirements and/or 
standards stated in paragraphs (a) and (b) above, the Contracting 
Officer may immediately suspend, in whole or in part, work and further 
payments under this contract until the Contractor corrects the 
noncompliance. Notice of the suspension may be communicated by telephone 
and confirmed in writing. If the Contractor fails to complete corrective 
action within the period of time designated in the Contracting Officer's 
written notice of suspension, the Contracting Officer may, in 
consultation with OPRR, NIH, terminate this contract in a whole or in 
part, and the Contractor's name may be removed form the list of those 
contractors with approved Health and Human Services Human Subject 
Assurances.


(End of clause)



Sec. 352.270-9  Care of laboratory animals.

    (a) The following provision shall be included in solicitations 
expected to involve vertebrate animals:

 Notice to Offerors of Requirement for Adequate Assurance of Protection 
                of Vertebrate Animal Subjects (SEP 1985)

    The PHS Policy on Humane Care and Use of Laboratory Animals by 
Awardee Institutions establishes a number of requirements for research 
activities involving animals. Before award may be made to an applicant 
organization, the organization shall file, with the Office for 
Protection from Research Risks (OPRR), National Institutes of Health 
(NIH), a written Animal Welfare Assurance which commits the organization 
to comply with the provisions of the PHS Policy on Humane Care and Use 
of Laboratory Animals by Awardee Institutions, the Animal Welfare Act, 
and the Guide for the Care and Use of Laboratory Animals prepared by the 
Institute of Laboratory Animal Resources. In accordance with the PHS 
Policy on Humane Care and Use of Laboratory Animals by Awardee 
Institutions, applicant organizations must establish a committee, 
qualified through the experience and expertise of its members, to 
oversee the institution's animal program, facilities and procedures. No 
award involving the use of animals shall be made unless the Animal 
Welfare Assurance has been approved by OPRR. Prior to award, the 
Contracting Officer will notify Contractor(s) selected for projects that 
involve live vertebrate animals that an Animal Welfare Assurance is 
required. The Contracting Officer will request that OPRR negotiate an 
acceptable Animal Welfare Assurance with

[[Page 83]]

those Contractor(s). For further information, OPRR may be contacted at 
NIH, Bethesda, Maryland 20892 (301-496-7041).

(End of provision)

    (b) The following clause shall be included in all solicitations and 
resultant contracts involving research on vertebrate animals:

               Care of Live Vertebrate Animals (JAN 2001)

    (a) Before undertaking performance of any contract involving animal 
related activities, the Contractor shall register with the Secretary of 
Agriculture of the United States in accordance with 7 U.S.C. 2136 and 9 
CFR sections 2.25 through 2.28. The Contractor shall furnish evidence of 
the registration to the Contracting Officer.
    (b) The Contractor shall acquire vertebrate animals used in research 
from a dealer licensed by the Secretary of Agriculture under 7 U.S.C. 
2133 and 9 CFR Sections 2.1-2.11, or from a source that is exempt from 
licensing under those sections.
    (c) The Contractor agrees that the care and use of any live 
vertebrate animals used or intended for use in the performance of this 
contract will conform with the PHS Policy on Humane Care of Use of 
Laboratory Animals, the current Animal Welfare Assurance, the Guide for 
the Care and Use of Laboratory Animals prepared by the Institute of 
Laboratory Animal Resources and the pertinent laws and regulations of 
the United States Department of Agriculture (see 7 U.S.C. 2131 et seq. 
and 9 CFR Subchapter A, Parts 1-4). In case of conflict between 
standards, the more stringent standard shall be used.
    (d) If at any time during performance of this contract, the 
Contracting Officer determines, in consultation with the Office for 
Protection from Research Risks (OPRR), National Institutes of Health 
(NIH), that the Contractor is not in compliance with any of the 
requirements and/or standards stated in paragraphs (a) through (c) 
above, the Contracting Officer may immediately suspend, in whole or in 
part, work and further payments under this contract until the Contractor 
corrects the noncompliance. Notice of the suspension may be communicated 
by telephone and confirmed in writing. If the Contractor fails to 
complete corrective action within the period of time designated in the 
Contracting Officer's written notice of suspension, the Contracting 
Officer may, in consultation with OPRR, NIH, terminate this contract in 
whole or in part, and the Contractor's name may be removed from the list 
of those contractors with approved PHS Animal Welfare Assurances.
    Note: Note: The Contractor may request registration of its facility 
and a current listing of licensed dealers from the Regional Office of 
the Animal and Plant Health Inspection Service (APHIS), USDA, for the 
region in which its research facility is located. The location of the 
appropriate APHIS Regional Office, as well as information concerning 
this program may be obtained by contacting the Animal Care Staff, USDA/
APHIS, 4700 River Road, Riverdale, Maryland 20737.


(End of Clause)

                             PART 353_FORMS

                  Subpart 353.3_Illustrations of Forms

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4262, Jan. 17, 2001, unless otherwise noted.



Sec. 353.370-674   Form HHS 674, Structured Approach Profit/Fee 
          Objective.

    This form is available from local cost advisory personnel. For 
copies of the form, contact the Program Support Center at (301) 443-
6740.

[[Page 84]]



                    SUBCHAPTER T_HHS SUPPLEMENTATIONS

             PART 370_SPECIAL PROGRAMS AFFECTING ACQUISITION

 Subpart 370.1_Accessibility of Meetings, Conferences, and Seminars to 
                        Persons With Disabilities

Sec.

Sec. 370.101  Policy.

Sec. 370.102  Responsibilities.

      Subpart 370.2_Indian Preference in Employment, Training, and 
                      Subcontracting Opportunities


Sec. 370.201  Statutory requirements.

Sec. 370.202  Applicability.

Sec. 370.203  Definitions.

Sec. 370.204  Compliance enforcement.

Sec. 370.205  Tribal preference requirements.

           Subpart 370.3_Acquisitions Involving Human Subjects


Sec. 370.300  Scope of subpart.

Sec. 370.301  Policy.

Sec. 370.302  Types of assurances.

Sec. 370.303  Notice to offerors.

Sec. 370.304  Contract clause.

   Subpart 370.4_Acquisitions Involving the Use of Laboratory Animals


Sec. 370.400  Scope of subpart.

Sec. 370.401  Policy.

Sec. 370.402  Assurances.

Sec. 370.403  Notice to offerors.

Sec. 370.404  Contract clause.

           Subpart 370.5_Acquisitions Under the Buy Indian Act


Sec. 370.500  Scope of subpart.

Sec. 370.501  Policy.

Sec. 370.502  Definitions.

Sec. 370.503  Requirements.

Sec. 370.504  Competition.

Sec. 370.505  Responsibility determinations.

    Authority: 5 U.S.C. 301; 40 U.S.C. 486(c).

    Source: 66 FR 4262, Jan. 17, 2001, unless otherwise noted.

 Subpart 370.1_Accessibility of Meetings, Conferences, and Seminars to 
                        Persons With Disabilities



Sec. 370.101  Policy.

    (a) It is the policy of HHS that all meetings, conferences, and 
seminars be accessible to persons with disabilities. For the purpose of 
this policy, accessibility is defined as both physical access to 
meeting, conference, and seminar sites, and aids and services to enable 
individuals with sensory disabilities to fully participate in meetings, 
conferences, and seminars.
    (b) In regard to acquisition, the policy is applicable to all 
contracts where the statement of work requires the contractor to conduct 
meetings, conferences, or seminars that are open to the public or 
involve HHS personnel, but not to ad hoc meetings that may be necessary 
or incidental to contract performance.



Sec. 370.102  Responsibilities.

    (a) The contracting officer shall include the clause in 352.270-1 in 
every solicitation and resulting contract when the statement of work 
requires the contractor to conduct meetings, conferences, or seminars in 
accordance with 370.101(b).
    (b) The project officer shall be responsible for obtaining, 
reviewing, and approving the contractor's plan, which is to be submitted 
in response to paragraph (a) of the contract clause in 352.270-1. A 
consolidated or master plan for contracts requiring numerous meetings, 
conferences, or seminars will be acceptable. The project officer, prior 
to approving the plan, should consult with the Office of Engineering 
Services serving the region where the meeting, conference, or seminar is 
to be held, to assure that the contractor's plan meets the accessibility 
requirements of the

[[Page 85]]

contract clause. The Office of Engineering Services should determine the 
adequacy of the contractor's plan, and notify the project officer, in 
writing, within ten (10) working days of receiving the request from the 
project officer.

      Subpart 370.2_Indian Preference in Employment, Training, and 
                      Subcontracting Opportunities



Sec. 370.201  Statutory requirements.

    Section 7(b) of the Indian Self-Determination and Education 
Assistance Act, Public Law 93-638, 88 Stat. 2205, 25 U.S.C. 450e(b), 
requires:

    ``Any contract, subcontract, grant, or subgrant pursuant to this 
Act, the Act of April 16, 1934 (48 Stat. 596), as amended, or any other 
Act authorizing Federal contracts with or grants to Indian organizations 
or for the benefit of Indians, shall require that to the greatest extent 
feasible:
    (1) Preferences and opportunities for training and employment in 
connection with the administration of such contracts or grants shall be 
given to Indians; and
    (b) Preference in the award of subcontracts and subgrants in 
connection with the administration of such contracts or grants shall be 
given to Indian organizations and to Indian-owned economic enterprises 
as defined in section 3 of the Indian Financing Act of 1974 (88 Stat. 
77).''



Sec. 370.202  Applicability.

    The Indian Preference clause set forth in 352.270-2 and the Indian 
Preference Program clause set forth in 352.270-3 have been developed to 
implement section 7 (b) of Public Law 93-638 for all activities of the 
Department. The clauses shall be used by any affected departmental 
contracting activity as follows, except solicitations issued and 
contracts awarded pursuant to Title I of Public Law 93-638 (25 U.S.C. 
450 et seq.) are exempted:
    (a) The Indian Preference clause (352.270-2) shall be included in 
each solicitation and resultant contract, regardless of dollar amount:
    (1) When the contract is to be awarded pursuant to an act 
specifically authorizing contracts with Indian organizations; or
    (2) Where the work to be performed under the contract is 
specifically for the benefit of Indians and is in addition to any 
incidental benefits which might otherwise accrue to the general public.
    (b) The Indian Preference Program clause (352.270-3) shall be 
included in each solicitation and resultant contract when:
    (1) The dollar amount of the acquisition is expected to equal or 
exceed $50,000 for nonconstruction work or $100,000 for construction 
work;
    (2) The Indian Preference clause is to be included in the 
solicitation and resultant contract; and
    (3) The determination is made, prior to solicitation, that the work 
to be performed under the resultant contract will take place in whole or 
in substantial part on or near an Indian reservation(s). In addition, 
the Indian Preference Program clause may be included in any solicitation 
and resultant contract below the $50,000 or $100,000 level for 
nonconstruction or construction contracts, respectively, but which meet 
the requirements of paragraphs (b)(2) and (3) of this section 370.202, 
and, in the opinion of the contracting activity, offer substantial 
opportunities for Indian employment, training, and subcontracting.



Sec. 370.203  Definitions.

    For purposes of this subpart 370.2, the following definitions shall 
apply:
    (a) Indian means a person who is a member of an Indian Tribe. If the 
contractor has reason to doubt that a person seeking employment 
preference is an Indian, the contractor shall grant the preference but 
shall require the individual to provide evidence within thirty (30) days 
from the Tribe concerned that the person is a member of the Tribe.
    (b) Indian Tribe means an Indian Tribe, pueblo, band, nation, or 
other organized group or community, including any Alaska Native Village 
or regional or village corporation as defined in or established pursuant 
to the Alaska Native Claims Settlement Act (85 Stat. 688, 43 U.S.C. 
1601) which is recognized as eligible for the special programs and 
services provided by the United States to Indians because of their 
status as Indians.
    (c) Indian organization means the governing body of any Indian Tribe 
or entity established or recognized by such

[[Page 86]]

governing body in accordance with the Indian Financing Act of 1974 (88 
Stat. 77, 25 U.S.C. 1451).
    (d) Indian-owned economic enterprise means any Indian-owned 
commercial, industrial, or business activity established or organized 
for the purpose of profit, provided that such Indian ownership shall 
constitute not less than 51 percent of the enterprise, and the ownership 
shall encompass active operation and control of the enterprise.
    (e) Indian reservation includes Indian reservations, public domain 
Indian allotments, former Indian reservations in Oklahoma, and land held 
by incorporated Native groups, regional corporations, and village 
corporations under the provisions of the Alaska Native Claims Settlement 
Act (85 Stat. 688, 43 U.S.C. 1601 et seq.)
    (f) On or near an Indian Reservation means on a reservation or 
reservations or within that area surrounding an Indian reservation(s) 
where a person seeking employment could reasonably be expected to 
commute to and from in the course of a work day.



Sec. 370.204  Compliance enforcement.

    (a) The concerned contracting activity shall be responsible for 
conducting periodic reviews to insure contractor compliance with the 
requirements of the clauses set forth in 352.270-2 and 352.270-3. These 
reviews may be conducted with the assistance of the Indian Tribe(s) 
concerned.
    (b) Complaints of noncomplaince with the requirements of the clauses 
set forth in 352.270-2 and 352.270-3 which are filed in writing with the 
contracting activity shall be promptly investigated and resolved by the 
contracting officer.



Sec. 370.205  Tribal preference requirements.

    (a) Where the work under a contract is to be performed on an Indian 
reservation, the contracting activity may supplement the clause set 
forth in 352.270-3 by adding specific Indian preference requirements of 
the Tribe on whose reservation the work is to be performed. The 
supplemental requirements shall be jointly developed for the contract by 
the contracting activity and the Tribe. Supplemental preference 
requirements must represent a further implementation of the requirements 
of section 7(b) of Public Law 93-638 and must be approved by the 
affected program director and approved for legal sufficiency by the 
Business and Administrative Law Division, OGC, or a regional attorney 
before being added to a solicitation and resultant contract. Any 
supplemental preference requirements to be added to the clause in 
352.270-3 shall be included in the solicitation and clearly identified 
in order to insure uniform understanding of the additional requirements 
by all prospective bidders or offerors.
    (b) Nothing in this part shall be interpreted to preclude Tribes 
from independently developing and enforcing their own tribal preference 
requirements. Such independently developed tribal preference 
requirements shall not, except as provided in paragraph (a) of this 
section, become a requirement in contracts covered under this subpart 
370.2, and must not conflict with any Federal statutory or regulatory 
requirement concerning the award and administration of contracts.

           Subpart 370.3_Acquisitions Involving Human Subjects



Sec. 370.300  Scope of subpart.

    This subpart applies to all research and development activities 
involving human subjects conducted under contract (see 45 CFR 46.102(d) 
and (f)).



Sec. 370.301  Policy.

    It is the policy of the Department of Health and Human Services 
(DHHS) that no contract involving human subjects shall be awarded until 
acceptable assurance has been given that the activity will be subject to 
initial and continuing review by an appropriate Institutional Review 
Board (IRB) as described in DHHS regulations at 45 CFR 46.103. An 
applicable Multiple Project Assurance (MPA) or Single Project Assurance 
(SPA), approved by the Office for Protection from Research Risks (OPRR), 
National Institutes of Health (NIH), shall be required of each 
contractor, subcontractor, or cooperating institution having 
responsibility for human subjects involved in performance of the 
contract. The OPRR, NIH,

[[Page 87]]

is responsible for negotiating assurances covering all DHHS-supported or 
DHHS-conducted activities involving human subjects. Contracting officers 
shall be guided by OPRR regarding nonaward or termination of a contract 
due to inadequate assurance or breach of assurance for protection of 
human subjects.



Sec. 370.302  Types of assurances.

    Assurances may be one of two types:
    (a) Multiple Project Assurance (MPA). An MPA describes the oversight 
procedures applicable to all DHHS-supported human subjects activities 
within an institution having a significant number of concurrent 
projects. An MPA listed in OPRR's current ``List of Institutions Which 
Have an Approved MPA'' will be considered acceptable for purposes of 
this policy.
    (b) Single Project Assurance (SPA). An SPA describes the oversight 
procedures applicable to a single DHHS-supported human subjects 
activity. SPAs may be approved in modified form to meet unusual 
requirements. SPAs are not solicited from institutions with OPRR 
approved MPAs. Copies of proposals selected for negotiation and 
requiring one or more SPAs shall be forwarded to the Human Subjects 
Assurance Branch, OPRR, NIH MSC 7507, 6100 Executive Blvd., Room 3B01, 
Rockville, Maryland 20892, as early as possible so that timely action 
may be taken to secure the SPA(s).



Sec. 370.303  Notice to offerors.

    (a) Solicitations shall contain the notice to offerors in 352.270-
8(a) whenever contract performance is expected to involve human 
subjects.
    (b) IRB approval of proposals submitted by institutions having an 
OPRR-approved MPA should be certified in the manner required by 
instructions for completion of the contract proposal; or by completion 
of a DHHS Form 310, Protection of Human Subjects Assurance 
Identification/Certification/Declaration; or by letter indicating the 
institution's OPRR-assigned MPA number, the date of IRB review and 
approval, and the type of review (convened or expedited). The date of 
IRB approval must not be more than 12 months prior to the deadline for 
proposal submission.
    (c) SPAs for contractors, subcontractors, or cooperating 
institutions generally will not be requested prior to determination that 
a contract proposal has been selected for negotiation. When an SPA is 
submitted, it provides certification for the initial contract period. No 
additional documentation is required. If the contract provides for 
additional years to complete the project, the noncompetitive renewal 
proposal shall be certified in the manner described in the preceding 
paragraph.



Sec. 370.304  Contract clause.

    The clause set forth in 352.270-8(b) shall be inserted in all 
solicitations and resultant contracts involving human subjects.

   Subpart 370.4_Acquisitions Involving the Use of Laboratory Animals



Sec. 370.400   Scope of subpart.

    This subpart applies to all research, research training and 
biological testing activities involving live vertebrate animals 
conducted under contract (see Public Health Service Policy on Humane 
Care and Use of Laboratory Animals (PHS Policy), Rev. 1986, Repr. 1996).



Sec. 370.401  Policy.

    (a) It is the policy of the Department of Health and Human Services 
(DHHS) and the Public Health Service agencies that no contract involving 
live vertebrate animals shall be awarded until acceptable assurance has 
been given that the activity will be subject to initial and continuing 
review by an appropriate Institutional Animal Care and Use Committee 
(IACUC) as described in the PHS Policy at IV. B. 6. and 7. An applicable 
Full Animal Welfare Assurance or Interinstitutional Agreement/Assurance, 
approved by the Office for Protection from Research Risks (OPRR), 
National Institutes of Health (NIH), shall be required of each 
contractor, subcontractor, or cooperating institution having 
responsibility

[[Page 88]]

for animal care and use involved in performance of the contract (see PHS 
Policy II., IV. A., and V. B.).
    (b) The OPRR, NIH, is responsible for negotiating assurances 
covering all DHHS/PHS-supported or DHHS/PHS-conducted activities 
involving the care and use of live vertebrate animals. Contracting 
officers shall be guided by OPRR regarding adequate animal care, and 
use, approval, disapproval, restriction, or withdrawal of approval of 
assurances (see PHS Policy V. A.).



Sec. 370.402  Assurances.

    (a) Assurances may be one of two types:
    (1) Full Animal Welfare Assurance (AWA). An AWA describes the 
institution's complete program for the care and use of animals, 
including but not limited to the facilities, occupational health, 
training, veterinary care, IACUC procedures and lines of authority and 
responsibility. An AWA listed in OPRR's list of institutions which have 
an approved full AWA will be considered acceptable for purposes of this 
policy.
    (2) Interinstitutional Agreement/Assurance (IAA). An IAA describes 
the arrangements between an offeror and usually a subcontractor where 
animal activities will occur. An IAA is limited to the specific award or 
single project.
    (b) Copies of proposals selected for negotiation and requiring an 
assurance shall be forwarded to the Assurance Branch, Division of Animal 
Welfare, OPRR, NIH MSC 7507, 6100 Executive Blvd., Room 3B01, Rockville, 
Maryland 20892, as early as possible in order that timely action may be 
taken to secure the necessary assurances.
    (c) A contractor providing animal care services at an assured 
entity, such as a Government-owned, contractor-operated (GOCO) site, 
does not need a separate assurance because the GOCO site normally covers 
the contractor services in the GOCO site assurance.



Sec. 370.403  Notice to offerors.

    Solicitations shall contain the notice to offerors in 352.270-9(a) 
whenever contract performance is expected to involve the use of live 
vertebrate animals.
    (a) For offerors having a full AWA on file with OPRR, IACUC approval 
of the use of animals shall be submitted in the manner required by 
instructions for completion of the contract proposal, but prior to the 
technical review of the proposal. The date of IACUC review and approval 
must not be more than 36 months prior to the deadline for proposal 
submission.]
    (b) Non-assured offerors are not required to submit assurances or 
IACUC approval with proposals. OPRR will contact contractors, 
subcontractors and cooperating institutions to negotiate necessary 
assurances and verify IACUC approvals when requested by appropriate 
DHHS/PHS staff.



Sec. 370.404  Contract clause.

    The clause set forth in 352.270-9(b) shall be included in all 
solicitations and resultant contracts involving the care and use of live 
vertebrate animals.

           Subpart 370.5_Acquisitions Under the Buy Indian Act



Sec. 370.500  Scope of subpart.

    This subpart sets forth the policy on preferential acquisition from 
Indians under the negotiation authority of the Buy Indian Act. 
Applicability of this subpart is limited to acquisitions made by or on 
behalf of the Indian Health Service of the Public Health Service.



Sec. 370.501  Policy.

    (a) The Indian Health Service will utilize the negotiation authority 
of the Buy Indian Act to give preference to Indians whenever the use of 
that authority is authorized and is practicable. The Buy Indian Act, 25 
U.S.C. 47, prescribes the application of the advertising requirements of 
section 3709 of the Revised Statutes to the acquisition of Indian 
supplies. As set out in 25 U.S.C. 47, the Buy Indian Act provides as 
follows:

    So far as may be practicable Indian labor shall be employed, and 
purchases of the products (including, but not limited to printing, 
notwithstanding any other law) of Indian industry may be made in open 
market in the discretion of the Secretary of the Interior.

    (b) The functions, responsibilities, authorities, and duties of the 
Secretary

[[Page 89]]

of the Interior for maintenance and operation of hospital and health 
facilities for Indians and for the conservation of the health of Indians 
are transferred to the Surgeon General of the United States under the 
supervision of the Secretary of Health and Human Services, 42 U.S.C. 
2001 (a). Accordingly, the Secretary of Health and Human Services is 
authorized to use the Buy Indian Act in the acquisition of products of 
Indian industry in connection with the maintenance and operation of 
hospital and health facilities for Indians and for the conservation of 
the health of Indians. This authority has been delegated exclusively to 
the Indian Health Service and is not available for use by any other HHS 
component (unless that component is making an acquisition on behalf of 
the Indian Health Service).
    (c) Use of the Buy Indian Act negotiation authority has been 
emphasized in subsequent legislation, particularly Public Law 94-437 and 
Public Law 96-537.



Sec. 370.502  Definitions.

    Buy Indian contract means any contract involving activities covered 
by the Buy Indian Act that is negotiated under the provisions of 41 
U.S.C. 252(c) and 25 U.S.C. 47 between an Indian firm and a contracting 
officer representing the Indian Health Service.
    Indian means a member of any tribe, pueblo, band, group, village or 
community that is recognized by the Secretary of the Interior as being 
Indian or any individual or group of individuals that is recognized by 
the Secretary of the Interior or the Secretary of Health and Human 
Services. The Secretary of Health and Human Services in making 
determinations may take into account the determination of the tribe with 
which affiliation is claimed.
    Indian firm means a sole enterprise, partnership, corporation, or 
other type of business organization owned, controlled, and operated by 
one or more Indians (including, for the purpose of sections 301 and 302 
of Public Law 94-437, former or currently federally recognized Indian 
tribes in the State of New York) or by an Indian firm; or a nonprofit 
firm organized for the benefit of Indians and controlled by Indians (see 
370.503(a)).
    Product of Indian industry means anything produced by Indians 
through physical labor or by intellectual effort involving the use and 
application of skills by them.



Sec. 370.503  Requirements.

    (a) Indian ownership. The degree of Indian ownership of an Indian 
firm shall be at least 51 percent during the period covered by a Buy 
Indian contract.
    (b) Joint ventures. An Indian firm may enter into a joint venture 
with other entities for specific projects as long as the Indian firm is 
the managing partner. However, the joint venture must be approved by the 
contracting officer prior to the award of a contract under the Buy 
Indian Act.
    (c) Bonds. In the case of contracts for the construction, 
alteration, or repair of public buildings or public works, performance 
and payment bonds are required by the Miller Act (40 U.S.C. 270a-270f) 
and FAR part 28. In the case of contracts with Indian tribes or public 
nonprofit organizations serving as governmental instrumentalities of an 
Indian tribe, bonds are not required. However, bonds are required when 
dealing with private business entities which are owned by an Indian 
tribe or members of an Indian tribe. Bonds may be required of private 
business entities which are joint ventures with, or subcontractors of, 
an Indian tribe or a public nonprofit organization serving as a 
governmental instrumentality of an Indian tribe. A bid guarantee or bid 
bond is required only when a performance or payment bond is required.
    (d) Indian preference in employment, training and subcontracting. 
Contracts awarded under the Buy Indian Act are subject to the 
requirements of section 7(b) of the Indian Self-Determination and 
Education Assistance Act 25 U.S.C. 450e, which requires that preference 
be given to Indians in employment, training, and subcontracting. The 
Indian Preference clause set forth in 352.270-2 shall be included in all 
Buy Indian solicitations and resultant contracts. The Indian Preference 
Program clause set forth in 352.270-3 shall be used as specified in 
370.202(b). All requirements

[[Page 90]]

set forth in subpart 370.2 which are applicable to the instant Buy 
Indian acquisition shall be followed by the contracting officer, e.g., 
sections 370.204 and 370.205.
    (e) Subcontracting. Not more than 50 percent of the work to be 
performed under a prime contract awarded pursuant to the Buy Indian Act 
shall be subcontracted to other than Indian firms. For this purpose, 
work to be performed does not include the provision of materials, 
supplies, or equipment.
    (f) Wage rates. A determination of the minimum wage rates by the 
Secretary of Labor as required by the Davis-Bacon Act (40 U.S.C. 276a) 
shall be included in all contracts awarded under the Buy Indian Act for 
over $2,000 for construction, alteration, or repair, including painting 
and decorating, of public buildings and public works, except contracts 
with Indian tribes or public nonprofit organizations serving as 
governmental instrumentalities of an Indian tribe. The wage rate 
determination is to be included in contracts with private business 
entities even if they are owned by an Indian tribe or a member of an 
Indian tribe and in connection with joint ventures with, or 
subcontractors of, an Indian tribe or a public nonprofit organization 
serving as a governmental instrumentality of an Indian tribe.



Sec. 370.504  Competition.

    (a) Contracts to be awarded under the Buy Indian Act shall be 
subject to competition among Indians or Indian concerns to the maximum 
extent that competition is determined by the contracting officer to be 
practicable. When competition is determined not to be practicable, a 
Justification for Other than Full and Open Competition shall be prepared 
in accordance with 306.303 and subsequently retained in the contract 
file.
    (b) Solicitations must be synopsized and publicized in the Commerce 
Business Daily and copies of the synopses sent to the tribal office of 
the Indian tribal government directly concerned with the proposed 
acquisition as well as to Indian concerns and others having a legitimate 
interest. The synopsis should state that the acquisition is restricted 
to Indian firms under the Buy Indian Act.



Sec. 370.505  Responsibility determinations.

    (a) A contract may be awarded under the Buy Indian Act only if it is 
first determined that the project or function to be contracted for is 
likely to be satisfactorily performed under that contract and the 
project or function is likely to be properly completed or maintained 
under that contract.
    (b) The determination called for by paragraph (a) of this section, 
to be made prior to the award of a contract, will be made in writing by 
the contracting officer reflecting an analysis of the standards set 
forth in FAR 9.104-1.

[[Page 91]]



                  CHAPTER 4--DEPARTMENT OF AGRICULTURE




                           (Parts 400 to 499)

  --------------------------------------------------------------------

                          SUBCHAPTER A--GENERAL
Part                                                                Page
401             Agriculture Acquisition Regulation System...          93
402             Definitions of words and terms..............          97
403             Improper business practices and personal 
                    conflicts of interest...................          98
404             Administrative matters......................         100
           SUBCHAPTER B--COMPETITION AND ACQUISITION PLANNING
405             Publicizing contract actions................         102
406             Competition requirements....................         102
407             Acquisition planning........................         103
408             Required sources of supplies and services...         104
409             Contractor qualifications...................         106
410

[Reserved]

411             Describing agency needs.....................         108
412             Acquisition of commercial items.............         109
          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
413             Simplified acquisition procedures...........         110
414             Sealed bidding..............................         110
415             Contracting by negotiation..................         111
416             Types of contracts..........................         113
417             Special contracting methods.................         114
418

[Reserved]

                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
419             Small business programs.....................         115
420-421

[Reserved]

422             Application of labor laws to Government 
                    acquisitions............................         116
423             Environment, conservation, occupational 
                    safety, and drug-free workplace.........         118
424             Protection of privacy and freedom of 
                    information.............................         121
425             Foreign acquisition.........................         121

[[Page 92]]

426             Other socioeconomic programs................         123
             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
427             Patents, data, and copyrights...............         125
428             Bonds and insurance.........................         125
429

[Reserved]

430             Cost Accounting Standards Administration....         126
431             Contract cost principles and procedures.....         127
432             Contract financing..........................         127
433             Protests, disputes and appeals..............         131
             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING
434             Major system acquisition....................         133
435             Research and development contracting........         134
436             Construction and architect-engineer 
                    contracts...............................         134
437             Service contracting.........................         137
438-440

[Reserved]

441             Acquisition of utility services.............         138
                    SUBCHAPTER G--CONTRACT MANAGEMENT
442             Contract administration.....................         139
443-444

[Reserved]

445             Government property.........................         139
446             Quality assurance...........................         140
447             Transportation..............................         140
448

[Reserved]

449             Termination of contracts....................         141
450             Extraordinary contractual actions...........         141
451

[Reserved]

                     SUBCHAPTER H--CLAUSES AND FORMS
452             Solicitation provisions and contract clauses         143
453             Forms.......................................         154

[[Page 93]]



                          SUBCHAPTER A_GENERAL

           PART 401_AGRICULTURE ACQUISITION REGULATION SYSTEM

Sec.

Sec. 401.000  Scope of part.

               Subpart 401.1_Purpose, Authority, Issuance


Sec. 401.101  Purpose.

Sec. 401.103  Authority.

Sec. 401.104  Applicability.

Sec. 401.105  Issuance.

Sec. 401.105-1  Publication and code arrangement.

Sec. 401.105-2  Arrangement of regulations.

Sec. 401.105-3  Copies.

Sec. 401.106  OMB approval under the Paperwork Reduction Act.

Sec. 401.170  Electronic access to regulatory information.

                      Subpart 401.2_Administration


Sec. 401.201  Maintenance of the FAR.

Sec. 401.201-1  The two councils.

              Subpart 401.3_Agency Acquisition Regulations


Sec. 401.301  Policy.

Sec. 401.304  Agency control and compliance procedures.

Sec. 401.370  Exclusions.

Sec. 401.371  AGAR Advisories.

Sec. 401.372  Departmental directives.

             Subpart 401.4_Deviations From the FAR and AGAR


Sec. 401.402  Policy.

Sec. 401.403  Individual deviations.

Sec. 401.404  Class deviations.

        Subpart 401.6_Contracting Authority and Responsibilities


Sec. 401.601  General.

Sec. 401.602  Contracting officers.

Sec. 401.602-3  Ratification of unauthorized commitments.

Sec. 401.603  Selection, appointment, and termination of appointment.

Sec. 401.603-1  General.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.



Sec. 401.000  Scope of part.

    This part presents basic policies and general information about the 
Department of Agriculture's (USDA) Acquisition Regulation, subsequently 
referred to as the AGAR. The AGAR is an integral part of the Federal 
Acquisition Regulations System.

               Subpart 401.1_Purpose, Authority, Issuance



Sec. 401.101  Purpose.

    (a) The AGAR provides for the codification and publication of 
uniform policies and procedures for acquisitions by contracting 
activities within USDA.
    (b) The purpose of the AGAR is to implement the Federal Acquisition 
Regulation (FAR), where further implementation is needed, and to 
supplement the FAR when coverage is needed for subject matter not 
covered in the FAR. The AGAR is not by itself a complete document, as it 
must be used in conjunction with the FAR.



Sec. 401.103  Authority.

    The AGAR and amendments thereto are issued under 5 U.S.C. 301 and 40 
U.S.C. 486(c). The Senior Procurement Executive (SPE) has the delegated 
authority to promulgate Departmental acquisition regulations.



Sec. 401.104  Applicability.

    The FAR and AGAR apply to all USDA acquisitions of supplies and 
services (including construction) which obligate appropriated funds, 
unless otherwise specified in this chapter or excepted by law.



Sec. 401.105  Issuance.



Sec. 401.105-1  Publication and code arrangement.

    (a) The AGAR is codified in the Code of Federal Regulations (CFR) as 
Chapter 4 of Title 48, Federal Acquisition Regulations System, to 
implement and supplement Chapter 1 which constitutes the FAR. Parts 400 
through 499 have been assigned to USDA by the Office of the Federal 
Register.
    (b) The AGAR and its subsequent changes are published in:

[[Page 94]]

    (1) Daily issues of the Federal Register,
    (2) Cumulative form in the CFR, and
    (3) Loose-leaf form for distribution within USDA.
    (c) Section 553(a)(2) of the Administrative Procedure Act, 5 U.S.C. 
553, provides an exception from the standard public rulemaking 
procedures to the extent that the rule involves a matter relating to 
agency management or personnel or to public property, loans, grants, 
benefits, or contracts. OFPP Policy Letter 83-2 requires rulemaking for 
substantive acquisition rules but allows discretion in the matter for 
other than significant issues meeting the stated criteria. The AGAR has 
been promulgated and may be revised from time to time in accordance with 
the rulemaking procedures of the Administrative Procedure Act and OFPP 
Policy Letter 83-2.



Sec. 401.105-2  Arrangement of regulations.

    AGAR coverage parallels the FAR in format, arrangement, and 
numbering system. However, subdivisions below the section and subsection 
levels may not always correlate directly to FAR designated paragraphs 
and subparagraphs.



Sec. 401.105-3  Copies.

    Copies of the AGAR published in CFR form may be purchased from the 
Superintendent of Documents, Government Printing Office, Washington, 
D.C. 20402. Requests should reference Chapter 4 of Title 48 CFR.



Sec. 401.106  OMB approval under the Paperwork Reduction Act.

    The following OMB control numbers apply to USDA solicitations and 
specified information collections within the AGAR:

------------------------------------------------------------------------
                                                             OMB Control
                        AGAR segment                             No.
------------------------------------------------------------------------
411.170....................................................    0505-0014
415.2......................................................    0505-0013
436.575....................................................    0505-0011
437.110....................................................    0505-0015
437.270....................................................    0505-0016
452.211-1..................................................    0505-0014
452.215-71.................................................    0505-0013
452.236-75.................................................    0505-0011
452.237-74.................................................    0505-0015
452.237-76.................................................    0505-0016
------------------------------------------------------------------------


[61 FR 53646, Oct. 15, 1996, as amended at 64 FR 52674, Sept. 30, 1999]



Sec. 401.170  Electronic access to regulatory information.

    The USDA Departmental Administration Procurement Homepage provides 
access to the AGAR, AGAR amendments (circulars), AGAR Advisories, and 
other USDA procurement policy and guidance in electronic form. The 
Internet address for the Procurement Homepage is URL http://
www.usda.gov/da/procure.html.

[63 FR 26994, May 15, 1998]

                      Subpart 401.2_Administration



Sec. 401.201  Maintenance of the FAR.



Sec. 401.201-1  The two councils.

    (a) USDA's representative on the Civilian Agency Acquisition Council 
is designated by the SPE.
    (b) The Procurement Policy Division will coordinate proposed FAR 
revisions with interested contracting activities.

              Subpart 401.3_Agency Acquisition Regulations



Sec. 401.301  Policy.

    (a) The SPE, subject to the authorities in 401.103 and FAR 1.301, 
may issue and publish Departmental regulations, that together with the 
FAR, constitute Department-wide policies, procedures, solicitation 
provisions, and contract clauses governing the contracting process or 
otherwise controlling the relationship between USDA (including any of 
its contracting activities) and contractors or prospective contractors.
    (b) Each designated head of a contracting activity (HCA) is 
authorized to issue or authorize the issuance of, at any organizational 
level, internal guidance which does not have a significant effect beyond 
the internal operating procedures of the activity, or a significant cost 
or administrative impact on offerors or contractors. Internal guidance 
issued by contracting activities will not be published in the Federal 
Register. HCA's shall ensure that the guidance, procedures, or 
instructions issued--

[[Page 95]]

    (1) Are consistent with the policies and procedures contained in 
this chapter;
    (2) Follow the format, arrangement, and numbering system of this 
chapter to the extent practicable;
    (3) Contain no material which duplicates, paraphrases, or is 
inconsistent with this chapter; and
    (4) Are numbered and identified by use of alphabetical suffixes to 
the chapter number as follows:

4A [Reserved]
4B Agricultural Research Service.
4C Farm Service Agency.
4D Rural Development (mission area).
4E Food Safety and Inspection Service.
4F [Reserved]
4G Forest Service.
4H [Reserved]
4I Natural Resources Conservation Service.
4J [Reserved]
4K Food and Consumer Service.
4L Animal and Plant Health Inspection Service.
4M [Reserved]
4N Office of Operations.
4O-4P [Reserved]
4R Office of Inspector General.
4S [Reserved]



Sec. 401.304  Agency control and compliance procedures.

    (a) The AGAR System is under the direct oversight and control of the 
SPE, who is responsible for review and issuance of all Department-wide 
acquisition regulations published in the Federal Register to assure 
compliance with FAR part 1.
    (b) The SPE is also responsible for review and issuance of 
unpublished, Department-wide internal guidance under the AGAR System.
    (c) HCA's are responsible for establishment and implementation of 
formal procedures for oversight and control of unpublished internal 
guidance issued within the contracting activity to implement FAR or AGAR 
requirements. These procedures shall be subject to the review and 
approval by the SPE.
    (d) The SPE is responsible for evaluating coverage under the AGAR 
System to determine applicability to other agencies and for recommending 
coverage to the FAR Secretariat for inclusion in the FAR.
    (e) Recommendations for revision of existing FAR coverage or new FAR 
coverage shall be submitted by the HCA to the SPE for further action.



Sec. 401.370  Exclusions.

    Subject to the policies of FAR subpart 1.3, certain USDA acquisition 
policies and procedures may be excluded from the AGAR under 
appropriately justified circumstances, such as:
    (a) Subject matter which is effective for a period less than 12 
months.
    (b) Subject matter which is instituted on an experimental basis for 
a reasonable period.
    (c) Acquisition procedures instituted on an interim basis to comply 
with the requirements of statute, regulation, Executive Order, OMB 
Circular, or OFPP Policy Letter.



Sec. 401.371  AGAR Advisories.

    The SPE may issue AGAR Advisories, consistent with the policies of 
the FAR and the AGAR, for the following purposes:
    (a) To communicate Department-wide policy and/or procedural guidance 
to contracting activities;
    (b) To delegate to procurement officials authority to make 
determinations or to take action to implement the policies of the FAR or 
the AGAR; and,
    (c) To establish internal policy and procedures on an interim basis, 
prior to incorporation in the AGAR or in a Departmental Directive.



Sec. 401.372  Departmental directives.

    Subject to the policies of FAR 1.3, USDA from time to time may issue 
internal directives to establish procedures, standards, guidance, or 
methods of performing duties, functions, or operations. Such directives 
include Departmental Regulations (DR's), Departmental Notices, and 
Secretary's Memoranda.

             Subpart 401.4_Deviations From the FAR and AGAR



Sec. 401.402  Policy.

    Requests for authority to deviate from the provisions of the FAR or 
the AGAR shall be submitted in writing as

[[Page 96]]

far in advance as the exigencies of the situation will permit. Each 
request for deviation shall contain the following:
    (a) A statement of the deviation desired, including identification 
of the specific paragraph number(s) of the FAR and AGAR;
    (b) The reason why the deviation is considered necessary or would be 
in the best interest of the Government;
    (c) If applicable, the name of the contractor and identification of 
the contract affected;
    (d) A statement as to whether the deviation has been requested 
previously and, if so, circumstances of the previous request;
    (e) A description of the intended effect of the deviation;
    (f) A statement of the period of time for which the deviation is 
needed; and
    (g) Any pertinent background information which will contribute to a 
full understanding of the desired deviation.



Sec. 401.403  Individual deviations.

    In individual cases, deviations from either the FAR or the AGAR will 
be authorized only when essential to effect a necessary acquisition or 
where special circumstances make such deviations clearly in the best 
interest of the Government. Except for cost principles, HCA's may 
approve individual deviations from the AGAR, after coordinating with the 
General Counsel and the SPE. No deviations from the FAR or AGAR may be 
authorized at the contracting office level. A copy of each deviation and 
its supporting documentation shall be provided to the SPE. Deviations 
from the FAR shall not be made unless such action is authorized by the 
SPE after consultation with the Office of the General Counsel and any 
other appropriate office, on the basis of a written justification 
stating clearly the special circumstances involved.



Sec. 401.404  Class deviations.

    Where deviations from the FAR or AGAR are considered necessary for 
classes of contracts, requests for authority to deviate shall be 
submitted in writing to the SPE for approval. The SPE may authorize 
class deviations from the FAR without consulting the Chairperson of the 
Civilian Agency Acquisition Council where urgency precludes 
consultation. The SPE shall subsequently inform the Chairperson of the 
Civilian Agency Acquisition Council of the deviation including the 
circumstances under which it was required.

        Subpart 401.6_Contracting Authority and Responsibilities



Sec. 401.601  General.

    (a) The authority and responsibility vested in the Secretary to 
manage USDA's acquisition function is delegated through the Assistant 
Secretary for Administration to the SPE. This broad authority includes, 
but is not limited to, the following responsibilities:
    (1) Prescribing and publishing Departmental acquisition policies, 
regulations, and procedures.
    (2) Taking any necessary actions consistent with policies, 
regulations, and procedures with respect to purchases, contracts, 
leases, and other transactions.
    (3) Designating contracting officers.
    (4) Establishing clear lines of contracting authority.
    (5) Evaluating and monitoring the performance of USDA's acquisition 
system.
    (6) Managing and enhancing career development of the contracting 
work force.
    (7) Participating in the development of Government-wide acquisition 
policies, regulations, and standards; and determining specific areas 
where government-wide performance standards should be established and 
applied.
    (8) Determining areas of Department-unique standards and developing 
unique Department-wide standards.
    (9) Certifying to the Secretary that the acquisition system meets 
approved standards.
    (b) The SPE may delegate contracting authority to the Heads of 
Contracting Activities (HCA's) and the responsibility to manage their 
acquisition function.
    (c) Unless prohibited by the FAR, the AGAR, or by other applicable 
statutes and regulations, the SPE may redelegate to HCA's the authority 
to make determinations as the agency head in

[[Page 97]]

order to implement the policies and procedures of the FAR. Such 
delegations shall be in writing, but need not be published.
    (d) Unless prohibited by the FAR, the AGAR, or by other applicable 
statutes or regulations, each HCA may designate one individual from the 
contracting activity to carry out the functions of the HCA (HCAD). The 
HCAD may exercise all authority delegated to the HCA.



Sec. 401.602  Contracting officers.



Sec. 401.602-3  Ratification of unauthorized commitments.

    (a) Definitions. Ratification, as used in this section, means the 
signed, documented action taken by an authorized official to approve and 
sanction a previously unauthorized commitment.
    Unauthorized commitment, as used in this section, means an agreement 
made by a Government representative who lacked the authority to enter 
into a contract on behalf of the Government.
    (b) Policy. The HCA may delegate ratification authority to the chief 
of the contracting office.
    (c) Procedure. Whenever an official of the cognizant contracting 
activity who is authorized to ratify unauthorized commitments learns 
that a person or firm has assumed work as a result of an unauthorized 
commitment, that official shall take the following actions:
    (1) Immediately inform any person who is performing work as a result 
of an unauthorized commitment that the work is being performed at that 
person's risk;
    (2) Inform the individual who made the unauthorized commitment of 
the seriousness of the act and the possible consequences;
    (3) Ensure that the individual who made the unauthorized commitment 
furnishes all records and documents concerning the commitment and a 
complete, written statement of facts, including, but not limited to: a 
statement as to why a contracting officer was not used; why the vendor 
was selected and a list of sources considered; a description of work to 
be performed or products to be furnished; the estimated or agreed price; 
whether an appropriation is available for the work; and whether 
performance has begun. Under exceptional circumstances, such as when the 
individual who made the unauthorized commitment is no longer available 
to attest to the circumstances of the unauthorized commitment, the 
ratifying official may waive these requirements; and
    (4) Decide whether ratification is proper and proceed as follows:
    (i) If ratification is not justifiable, provide the cognizant 
program office, contracting office, and the unauthorized contractor with 
an explanation of the decision not to ratify.
    (ii) If ratification appears adequately justified, ratify the action 
and retain or assign the contract to a successor contracting officer if 
necessary.
    (iii) Maintain related approval, decisional, and background 
documents in the contract file for audit purposes.
    (iv) Notify the cognizant program supervisor or line officer about 
the final disposition of the case; the notification may include a 
recommendation that the unauthorized commitment should be further 
considered a violation of USDA's employee conduct regulations.



Sec. 401.603  Selection, appointment, and termination of appointment.



Sec. 401.603-1  General.

    An HCA may delegate contracting authority to the extent authorized 
by the SPE in a general delegation of acquisition authority, by 
appointing qualified individuals as contracting officers, in accordance 
with the USDA Contracting Officer Warrant System, Departmental 
Regulation 5001-1.

                 PART 402_DEFINITIONS OF WORDS AND TERMS

Sec.

Sec. 402.000  Scope of part.

                        Subpart 402.1_Definitions


Sec. 402.101  Definitions.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

[[Page 98]]



Sec. 402.000  Scope of part.

    As used throughout this chapter, the following words and terms are 
used as defined in this subpart unless the context in which they are 
used clearly requires a different meaning, or a different definition is 
prescribed for a particular part or portion of a part.

                        Subpart 402.1_Definitions



Sec. 402.101  Definitions.

    Acquisition official means an individual who has been delegated 
authority to manage or to exercise acquisition functions and 
responsibilities.
    Agency head or Head of the Agency means the Secretary of 
Agriculture, Deputy Secretary, or the Assistant Secretary for 
Administration.
    Head of the contracting activity (HCA) means the official who has 
overall responsibility for managing the contracting activity (i.e., 
Chief, Forest Service; Administrator, Agricultural Research Service; 
etc.), or the individual designated by such an official to carry out the 
functions of the HCA.
    Senior Procurement Executive (SPE) means the agency official 
appointed as such by the head of the agency pursuant to Executive Order 
12931. The Director, Office of Procurement and Property Management, has 
been designated as the USDA SPE.

[61 FR 53646, Oct. 15, 1996, as amended at 63 FR 26994, May 15, 1998]

 PART 403_IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST

                        Subpart 403.1_Safeguards

Sec.

Sec. 403.101  Standards of conduct.

Sec. 403.101-3  Agency regulations.

Sec. 403.104  Procurement integrity.

Sec. 403.104-5  [Reserved]

Sec. 403.104-10  Violations or possible violations.

       Subpart 403.2_Contractor Gratuities to Government Personnel


Sec. 403.203  Reporting suspected violations of the gratuities clause.

Sec. 403.204  Treatment of violations.

         Subpart 403.3_Reports of Suspected Antitrust Violations


Sec. 403.303  Reporting suspected antitrust violations.

                      Subpart 403.4_Contingent Fees


Sec. 403.409  Misrepresentations or violations of the Covenant Against 
          Contingent Fees.

             Subpart 403.5_Other Improper Business Practices


Sec. 403.502  Subcontractor kickbacks.

Subpart 403.6_Contracts With Government Employees or Organizations Owned 
                          or Controlled by Them


Sec. 403.602  Exceptions.

Sec. 403.603  Responsibilities of the contracting officer.

 Subpart 403.8_Limitation on the Payment of Funds to Influence Federal 
                              Transactions


Sec. 403.806  Processing suspected violations

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                        Subpart 403.1_Safeguards



Sec. 403.101  Standards of conduct.



Sec. 403.101-3  Agency regulations.

    (a) The standards of conduct for USDA procurement officials are the 
uniform standards established by the Office of Government Ethics in 5 
CFR Part 2635, Standards of Ethical Conduct for Employees of the 
Executive Branch, and FAR 3.104, Procurement integrity.
    (b) Procurement officials and other employees who require advice 
concerning the application of standards of conduct to any acquisition 
issue shall obtain ethics advisory opinions from

[[Page 99]]

ethics advisory officials in their agency personnel offices.



Sec. 403.104  Procurement integrity.



Sec. 403.104-5  [Reserved]



Sec. 403.104-10  Violations or possible violations.

    (a) The contracting officer shall forward information concerning any 
violation or possible violation of the Procurement Integrity Act (41 
U.S.C. 423) to the chief of the contracting office.
    (b) Heads of contracting activities (HCA's) or their designees who 
receive information concerning any violation or possible violation of 
the Act shall take action in accordance with FAR 3.104-10(b).

[61 FR 53646, Oct. 15, 1996, as amended at 63 FR 26995, May 15, 1998]

       Subpart 403.2_Contractor Gratuities to Government Personnel



Sec. 403.203  Reporting suspected violations of the gratuities clause.

    A suspected violation of the contract clause, FAR 52.203-3, 
Gratuities, shall be reported immediately to the cognizant contracting 
officer in writing, stating the circumstances surrounding the 
incident(s), the date(s), and names of all parties involved. The 
contracting officer shall review the report for completeness, add any 
additional information deemed necessary and a recommendation for action, 
and submit the report to the HCA.



Sec. 403.204  Treatment of violations.

    The HCA shall review the report and consult with the Offices of 
General Counsel and Inspector General to determine whether further 
action should be pursued. If it is found that the facts and 
circumstances warrant further action, the HCA shall give the contractor 
a formal written notice which summarizes the reported violation and 
affords the contractor the opportunity to make a written or oral 
response within a reasonable, specified period after receipt of the 
notice. The notice shall be sent by certified mail with return receipt 
requested. Oral presentations shall follow the procedures outlined in 
FAR 3.204(b). The HCA shall furnish copies of any adverse determination 
to the contracting officer and the Department Debarring Officer for 
their subsequent considerations under FAR 3.204(c)(1) and (2), 
respectively.

         Subpart 403.3_Reports of Suspected Antitrust Violations



Sec. 403.303  Reporting suspected antitrust violations.

    Contracting officers shall report the circumstances of suspected 
violations of antitrust laws to the Office of Inspector General in 
accordance with procedures in Departmental Regulations (1700 series).

                      Subpart 403.4_Contingent Fees



Sec. 403.409  Misrepresentations or violations of the Covenant Against 
          Contingent Fees.

    (a) A suspected misrepresentation or violation of the Covenant 
Against Contingent Fees shall be documented in writing by the 
contracting officer and reported immediately to the chief of the 
contracting office. The chief of the contracting office shall determine 
if a violation has occurred and report any violation to the Office of 
Inspector General. The chief of the contracting office shall take action 
in accordance with FAR 3.409(b).
    (b) If the chief of the contracting office decides to refer the case 
to the Department of Justice, it should be referred through the Office 
of Inspector General with a copy of the report and referral submitted 
through the HCA to the Senior Procurement Executive.

             Subpart 403.5_Other Improper Business Practices



Sec. 403.502  Subcontractor kickbacks.

    Contracting officers shall report the circumstances of suspected 
violations of the Anti-Kickback Act (41 U.S.C. 51-54) to the Office of 
Inspector General in accordance with procedures in Departmental 
Regulations (1700 series).

[[Page 100]]

Subpart 403.6_Contracts With Government Employees or Organizations Owned 
                          or Controlled by Them



Sec. 403.602  Exceptions.

    The HCA is authorized to accept a contract from the policy in FAR 
3.601.



Sec. 403.603  Responsibilities of the contracting officer.

    The contracting officer, when requesting authorization under 
403.602, shall prepare a written determination and findings for the 
signature of the HCA. The determination shall document compliance with 
FAR 3.603, specifying the compelling reason(s) for award, and shall be 
placed in the contract file.

 Subpart 403.8_Limitation on the Payment of Funds to Influence Federal 
                              Transactions



Sec. 403.806  Processing suspected violations.

    Suspected violations of the requirements of 31 U.S.C. 1352 shall be 
referred to the Office of Inspector General in accordance with 
procedures in Departmental Regulations (1700 series).

                     PART 404_ADMINISTRATIVE MATTERS

    Subpart 404.4_Safeguarding Classified Information Within Industry

Sec.

Sec. 404.403  Responsibilities of contracting officers.

                    Subpart 404.6_Contract Reporting


Sec. 404.601  Record requirements.

Sec. 404.602  Federal Procurement Data System.

                      Subpart 404.8_Contract Files


Sec. 404.870  Document numbering system.

Sec. 404.870-1  Purchase order/delivery order numbering system.

Sec. 404.870-2  Contract numbering system.

                   Subpart 404.70_Precontract Notices


Sec. 404.7001  Solicitation provision.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

    Subpart 404.4_Safeguarding Classified Information Within Industry



Sec. 404.403  Responsibilities of contracting officers.

    When a proposed solicitation is likely to require access to 
information classified by USDA, the contracting officer shall consult 
with the Director of Human Resources Management within the Policy 
Analysis and Coordination Center of the Office of Assistant Secretary 
for Administration, regarding the procedures that must be followed.

                    Subpart 404.6_Contract Reporting



Sec. 404.601  Record requirements.

    The Senior Procurement Executive (SPE) manages an automated 
procurement reporting system for USDA. This system provides the Federal 
Procurement Data System with all required contracting information.



Sec. 404.602  Federal Procurement Data System.

    Contracting activities shall report contract actions into the USDA 
Procurement Reporting System in accordance with the instructions issued 
or distributed by the SPE.

                      Subpart 404.8_Contract Files



Sec. 404.870  Document numbering system.



Sec. 404.870-1  Purchase order/delivery order numbering system.

    USDA purchasing activities shall number their purchase/delivery 
orders in accordance with NFC Procedures Manual, ``Purchase Orders,'' 
Title II, Section 5.1.



Sec. 404.870-2  Contract numbering system.

    Contracting offices shall assign an 8 to 12-digit number to all 
contracts. Contract numbers will be divided into four data elements and 
formatted as follows:

(1)                                    (2)       (3)                 (4)
------------------------------------------------------------------------

[[Page 101]]

 
                   Transaction Ordering Fiscal Control
Code                                Office      Year              Number
------------------------------------------------------------------------
XX                                    XXXX         X          X to XXXXX
------------------------------------------------------------------------
 

    (a) Transaction code. This two-position code identifies the contract 
as being one of the following types:

    (1) Code 50--construction contract;
    (2) Code 51--[Reserved]
    (3) Code 52--tree planting/thinning contract;
    (4) Code 53--service contract;
    (5) Code 54--supply contract;
    (6) Code 55--aircraft rental (for fire-fighting purposes only) 
contract;
    (7) Code 56--personal equipment rental (rental of vehicular 
equipment for firefighting purposes only) contract;
    (8) Code 57--leasehold interest in real property contract.

    (b) Ordering office. This four-position code corresponds to the last 
four characters of the contracting office's GSA assigned FEDSTRIP 
requisitioner number.
    (c) Fiscal year. This one-position code corresponds to the last 
digit of the fiscal year in which the contract becomes effective.
    (d) Control number. This up-to-five position code (from one to five 
characters may be used) will be assigned by the contracting office. 
While contracts will generally be numbered consecutively (1 through 
99999), contracting offices may assign codes in any manner of their 
choosing. Codes may not be repeated, however, unless one of the 
preceding data elements (transaction code, ordering office, or fiscal 
year) changes. Alpha characters as well as numerals may be used in any 
one or more of the five positions.

                   Subpart 404.70_Precontract Notices



Sec. 404.7001  Solicitation provision.

    The contracting officer shall insert the provision at 452.204-70, 
Inquiries, in all solicitations.

[[Page 102]]



            SUBCHAPTER B_COMPETITION AND ACQUISITION PLANNING

                  PART 405_PUBLICIZING CONTRACT ACTIONS

                Subpart 405.3_Synopses of Contract Awards

Sec.

Sec. 405.303  Announcement of contract awards.

                  Subpart 405.4_Release of Information


Sec. 405.403  Requests from Members of Congress.

Sec. 405.404  Release of long-range acquisition estimates.

Sec. 405.404-1  Release procedures.

                    Subpart 405.5_Paid Advertisements


Sec. 405.502  Authority.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                Subpart 405.3_Synopses of Contract Awards



Sec. 405.303  Announcement of contract awards.

    Contracting officers shall make information available on any 
contract award with an estimated total value over $1 million (including 
options) to their agency congressional liaison office in sufficient time 
for the agency to announce it by 5:00 p.m. Washington, DC time on the 
day of award. The agency congressional liaison office shall, concurrent 
with the public announcement, provide the award announcement information 
to the USDA Congressional Relations Office.

                  Subpart 405.4_Release of Information



Sec. 405.403  Requests from Members of Congress.

    The head of the contracting activity (HCA) is the agency head 
designee pursuant to FAR 5.403(a).



Sec. 405.404  Release of long-range acquisition estimates.



Sec. 405.404-1  Release procedures.

    (a) HCA's shall establish written procedures to control the release 
of long-range acquisition estimates, as authorized under FAR 5.404-1.
    (b) Classified information shall not be released without the 
approval of the USDA Security Officer, Policy Analysis and Coordination 
Center--Human Resources Management. Departmental Manual and Regulation 
(3400 series) contain guidance on classified information.

                    Subpart 405.5_Paid Advertisements



Sec. 405.502  Authority.

    (a) The authority vested in the agency head to authorize publication 
of paid advertisements in newspapers (44 U.S.C. 3702) is delegated, with 
power of redelegation, to HCA's. HCA redelegation of this authority 
shall be in writing.
    (b) Policies and procedures regarding prior authorization required 
for media other than newspapers are contained in USDA Departmental 
Regulations 1400 series.

                    PART 406_COMPETITION REQUIREMENTS

   Subpart 406.2_Full and Open Competition After Exclusion of Sources

Sec.

Sec. 406.202  Establishing or maintaining alternative sources.

           Subpart 406.3_Other Than Full and Open Competition


Sec. 406.302  Circumstances permitting other than full and open 
          competition.

Sec. 406.302-70  Otherwise authorized by law.

                   Subpart 406.5_Competition Advocates


Sec. 406.501  Requirements.

    Authority: 5 U.S.C. and 40 U.S.C. 486(c).

[[Page 103]]


    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

   Subpart 406.2_Full and Open Competition After Exclusion of Sources



Sec. 406.202  Establishing or maintaining alternative sources.

    The Senior Procurement Executive is authorized to make 
determinations pursuant to FAR 6.202(a) and sign the determination and 
findings required by FAR 6.202(b).

           Subpart 406.3_Other Than Full and Open Competition



Sec. 406.302  Circumstances permitting other than full and open 
          competition.



Sec. 406.302-70  Otherwise authorized by law.

    (a) Authority. Section 1472 of the National Agricultural Research, 
Extension, and Teaching Policy Act of 1977 (7 U.S.C. 3318) (the Act) 
authorizes the Secretary of Agriculture to award contracts, without 
competition, to further research, extension, or teaching programs in the 
food and agricultural sciences.
    (b) Limitations. The use of this authority is limited to those 
instances where it can be determined that contracting without full and 
open competition is in the best interest of the Government and necessary 
to the accomplishment of the research, extension, or teaching program. 
Therefore:
    (1) Contracts under the authority of the Act shall be awarded on a 
competitive basis to the maximum practicable extent.
    (2) When full and open competition is not deemed appropriate, the 
contracting officer shall make a written justification on a case-by-case 
basis in accordance with procedures in FAR 6.303 and 6.304.

                   Subpart 406.5_Competition Advocates



Sec. 406.501  Requirements.

    (a) The Chief, Procurement Policy Division, Procurement and Property 
Management, Policy Analysis and Coordination Center, has been designated 
as the Competition Advocate for USDA.
    (b) Each HCA shall designate a competition advocate for the 
contracting activity.

                      PART 407_ACQUISITION PLANNING

                     Subpart 407.1_Acquisition Plans

Sec.

Sec. 407.103  Agency-head responsibilities.

Sec. 407.170  Advance acquisition plans.

         Subpart 407.3_Contractor Versus Government Performance


Sec. 407.302  General.

             Subpart 407.5_Inherently Governmental Functions


Sec. 407.503  Policy.

    Authority: 5 U.S.C. 301 and 40 U.S.C.

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                     Subpart 407.1_Acquisition Plans



Sec. 407.103  Agency-head responsibilities.

    Heads of Contracting Activities (HCA's) shall develop procedures to 
comply with FAR 7.103.



Sec. 407.170  Advance acquisition plans.

    Each HCA shall implement an advance acquisition planning system in 
accordance with procedures in Departmental Directives (5000 series).

         Subpart 407.3_Contractor Versus Government Performance



Sec. 407.302  General.

    The requirements of FAR subpart 7.3 and OMB Circular A-76 are 
implemented by Departmental Directives (2100 series).

             Subpart 407.5_Inherently Governmental Functions



Sec. 407.503  Policy.

    (a) HCA's shall establish procedures to ensure that requesting 
activities

[[Page 104]]

provide the written determination required by FAR 7.503(e), when 
submitting requests for procurement of services.
    (b) In the event of a disagreement as to whether the functions to be 
performed are inherently governmental, the HCA may refer the matter to 
the Senior Procurement Executive (SPE) for resolution. When submitting 
disagreements to the SPE for resolution the HCA shall provide a summary 
of the areas of disagreement, supported by the following:
    (1) The HCA's assessment of whether the services are ``inherently 
governmental'';
    (2) The basis for that assessment (include references to the 
definition and policy in FAR subpart 7.5 and/or Office of Federal 
Procurement Policy letter 92-1);
    (3) A copy of the statement of work; and,
    (4) The requesting activity's written determination in accordance 
with FAR 7.503(e).
    (c) Such disagreements shall be resolved prior to issuance of the 
solicitation.

[61 FR 53646, Oct. 15, 1996, as amended at 63 FR 26995, May 15, 1998]

           PART 408_REQUIRED SOURCES OF SUPPLIES AND SERVICES

                 Subpart 408.4_Federal Supply Schedules

Sec.

Sec. 408.404  Using schedules.

Sec. 408.404-3  Requests for waivers.

 Subpart 408.7_Acquisition From Nonprofit Agencies Employing People Who 
                     Are Blind or Severely Disabled


Sec. 408.701  Definitions.

Sec. 408.705  Procedures.

Sec. 408.705-2  Direct order process.

Sec. 408.705-3  Allocation process.

Sec. 408.705-4  Compliance with orders.

Sec. 408.706  Purchase exemptions.

Sec. 408.707  Prices.

Sec. 408.711  Quality complaints.

Sec. 408.712  Specification changes.

Sec. 408.714  Communications with the central nonprofit agencies and the 
          Committee.

       Subpart 408.8_Acquisition of Printing and Related Supplies


Sec. 408.802  Policy.

                Subpart 408.11_Leasing of Motor Vehicles


Sec. 408.1103  Contract requirements.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                 Subpart 408.4_Federal Supply Schedules



Sec. 408.404  Using schedules.



Sec. 408.404-3  Requests for waivers.

    A copy of the request for a waiver and the approval shall be placed 
in the contract file to support the acquisition of items off schedule.

 Subpart 408.7_Acquisition From Nonprofit Agencies Employing People Who 
                     Are Blind or Severely Disabled



Sec. 408.701  Definitions.

    Committee Member is the Presidential appointee representing USDA as 
a member of the Committee for Purchase from People Who Are Blind or 
Severely Disabled.
    Organization head is the head of the contracting activity (HCA), the 
head of a USDA corporation (as described in 31 U.S.C. 9101), or the head 
of a USDA staff office.



Sec. 408.705  Procedures.

    (a) The organization head shall appoint one person as Javits-Wagner-
O'Day Act (JWOD) Advocate to represent the organization and to 
coordinate the organization's actions with the Committee Member.
    (b) JWOD advocates may represent more than one organization. 
Advocates need not be acquisition officials.
    (c) The organization head shall issue and maintain an action plan to 
promote and enhance the organization's acquisitions from JWOD 
participating nonprofit agencies.
    (d) The action plan shall:
    (1) Announce the organization's support for the JWOD Act;
    (2) Establish a promotion program for the products and services 
provided by the JWOD participating nonprofit agencies;

[[Page 105]]

    (3) Provide for the JWOD Advocate's role in acquisition planning;
    (4) Establish measurable program goals for growth or other 
accomplishment in the organization's JWOD program actions; and
    (5) Establish an awards program for successful participation in the 
JWOD program.



Sec. 408.705-2  Direct order process.

    (a) The chief of a contracting office may apply to a central 
nonprofit agency for authorization to order specific supplies or 
services directly from a JWOD participating nonprofit agency.
    (b) A copy of the application should be provided to the JWOD 
Advocate who will inform the USDA Committee Member.



Sec. 408.705-3  Allocation process.

    (a) The chief of a contracting office may apply to a central 
nonprofit agency for a production allocation of specific supplies or 
services to a JWOD participating nonprofit agency.
    (b) A copy of the application should be provided to the JWOD 
Advocate who will inform the USDA Committee Member.



Sec. 408.705-4  Compliance with orders.

    Prior to attempting to resolve a failure to perform by a 
participating nonprofit agency with the Committee, the chief of the 
contracting office should provide advance notice to the JWOD Advocate 
who will inform the USDA Committee Member.



Sec. 408.706  Purchase exemptions.

    Prior to applying to the Committee for a purchase exemption, the 
chief of the contracting office should provide advance notice to the 
JWOD Advocate who will inform the USDA Committee Member.



Sec. 408.707  Prices.

    Prior to applying for a price revision, the chief of the contracting 
office should provide advance notice to the JWOD Advocate who will 
inform the USDA Committee Member.



Sec. 408.711  Quality complaints.

    Prior to attempting to resolve a complaint regarding the quality of 
goods or services provided by participating nonprofit agency with the 
Committee, the chief of the contracting office should provide advance 
notice to the JWOD Advocate who will inform the USDA Committee Member.



Sec. 408.712  Specification changes.

    Prior to providing 90-days advance notification to the Committee on 
actions that affect supplies and services on the Procurement List, the 
chief of the contracting office should provide advance notice to the 
JWOD Advocate who will inform the USDA Committee Member.



Sec. 408.714  Communications with the central nonprofit agencies and the 
          Committee.

    Any matter requiring referral to the Committee shall be provided to 
the JWOD Advocate who will coordinate the matter with the Committee 
Member.

       Subpart 408.8_Acquisition of Printing and Related Supplies



Sec. 408.802  Policy.

    (a) The Director, Office of Communications (OC) has been designated 
as the central printing authority in USDA, with the authority to 
represent the USDA before the Joint Committee on Printing (JCP), the 
Government Printing Office, and other Federal and State agencies on all 
matters related to printing.
    (b) Prior to contracting for any of the items defined in FAR 8.801, 
the contracting officer shall verify that the requisite approval has 
been received by the publication liaison officer or requisitioner.
    (c) The approval from OC or the approval authority designated by OC 
shall be maintained in the contract file.

                Subpart 408.11_Leasing of Motor Vehicles



Sec. 408.1103  Contract requirements.

    If the requirement includes the need for the vendor to provide 
operational maintenance such as oil and other fluid

[[Page 106]]

changes or replenishment, the contracting officer shall include in the 
contract (1) a requirement for fluids containing the maximum available 
amounts of recovered materials; and (2) a preference for either 
retreaded tires meeting the Federal retread specifications or retreading 
services for the tires on the vehicle.

                   PART 409_CONTRACTOR QUALIFICATIONS

          Subpart 409.4_Debarment, Suspension and Ineligibility

Sec.

Sec. 409.403  Definitions.

Sec. 409.404  List of parties excluded from Federal procurement and 
          nonprocurement programs.

Sec. 409.405  Effect of listing.

Sec. 409.405-1  Continuation of current contracts.

Sec. 409.405-2  Restrictions on subcontracting.

Sec. 409.406  Debarment.

Sec. 409.406-3  Procedures.

Sec. 409.407  Suspension.

Sec. 409.407-3  Procedures.

Sec. 409.470  Appeals.

    Subpart 409.5_Organizational and Consultant Conflicts of Interest


Sec. 409.503  Waiver.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

          Subpart 409.4_Debarment, Suspension and Ineligibility



Sec. 409.403  Definitions.

    Debarring official. Pursuant to the Secretary's delegations of 
authority in 7 CFR 2.24, the Senior Procurement Executive (SPE) is 
designated as the debarring official (Department Debarring Officer) with 
the following exceptions:
    (a) For commodity contracts awarded on behalf of the Commodity 
Credit Corporation (CCC), the Executive Vice President, CCC, or his 
designee is designated as the debarring official pursuant to 7 CFR part 
1407.
    (b) For contracts awarded under the School Lunch and Surplus Removal 
Programs (42 U.S.C. 1755 and 7 U.S.C. 612c), the Department Debarring 
Officer has delegated debarring authority to the Agricultural Marketing 
Service (AMS).

[63 FR 26995, May 15, 1998]



Sec. 409.404  List of parties excluded from Federal procurement and 
          nonprocurement programs.

    The Department Debarring Officer is USDA's single point of contact 
with GSA for debarment and suspension actions taken under this subpart. 
The debarring official for AMS shall notify the Department Debarring 
Officer of each debarment and suspension action by promptly submitting a 
copy of the debarment or suspension notice and any later changes to the 
debarment or suspension status. The Department Debarring Officer will 
forward a copy of each notice to GSA for inclusion in the Government-
wide list.



Sec. 409.405  Effect of listing.

    Compelling reasons are considered to be present where failure to 
contract with the debarred or suspended contractor would seriously harm 
the agency's programs and prevent accomplishment of mission 
requirements. The SPE is authorized to make the determinations under FAR 
9.405. Requests for such determinations shall be submitted through the 
head of the contracting activity (HCA) to the SPE.



Sec. 409.405-1  Continuation of current contracts.

    The HCA is authorized to make the determinations under FAR 9.405-1.



Sec. 409.405-2  Restrictions on subcontracting.

    The HCA is authorized to approve subcontracts with debarred or 
suspended subcontractors under FAR 9.405-2.



Sec. 409.406  Debarment.



Sec. 409.406-3  Procedures.

    (a) Investigation and referral. When a contracting officer becomes 
aware of possible irregularities or any information which may be 
sufficient cause for debarment, the case shall be immediately referred 
through the HCA to the debarring official. The case must be accompanied 
by a complete statement of the facts (including a copy of

[[Page 107]]

any criminal indictments, if applicable) along with a recommendation for 
action. Where the statement of facts indicates the irregularities to be 
possible criminal offenses, or for any other reason further 
investigation is considered necessary, the matter shall be referred to 
the HCA who should consult with the Office of Inspector General to 
determine if further investigation is required prior to referring to the 
debarring official.
    (b) Decision-making process. If, after reviewing the recommendations 
and consulting with the Office of Inspector General and Office of the 
General Counsel, as appropriate, the debarring official determines 
debarment is justified, the debarring official shall initiate the 
proposed debarment in accordance with FAR 9.406-3(c) and notify the HCA 
of the action taken.
    (c) Fact-finding proceeding. For actions listed under FAR 9.406-
3(b)(2), the contractor shall be given the opportunity to appear at an 
informal hearing. The hearing should be held at a location and time that 
is convenient to the parties concerned, if at all possible. The 
contractor and any specifically named affiliates may be represented by 
counsel or any duly authorized representative. Witnesses may be called 
by either party. The proceedings shall be conducted expeditiously and in 
such a manner that each party will have an opportunity to present all 
information considered pertinent to the proposed debarment. The 
contractor shall be provided a copy of a transcript of the proceedings 
under the conditions established in FAR 9.406-3(b)(2)(ii).



Sec. 409.407  Suspension.



Sec. 409.407-3  Procedures.

    (a) Investigation and referral. When a contracting officer becomes 
aware of possible irregularities or any information which may be 
sufficient cause for suspension, the case shall be immediately referred 
through the HCA to the debarring official. The case must be accompanied 
by a complete statement of the facts along with a recommendation for 
action. Where the statement of facts indicates the irregularities to be 
possible criminal offenses, or for any other reason further 
investigation is considered necessary, the matter shall be referred to 
the HCA who should consult with the Office of Inspector General to 
determine if further investigation is required prior to referring it to 
the debarring official.
    (b) Decision-making process. If, after reviewing the recommendations 
and consulting with the Office of Inspector General and Office of the 
General Counsel, as appropriate, the debarring official determines 
suspension is justified, the debarring official shall initiate the 
proposed suspension in accordance with FAR 9.407-3(c) and notify the HCA 
of the action taken.
    (c) Fact-finding proceedings. For actions listed under FAR 9.407-
3(b)(2), the contractor shall be given the opportunity to appear at an 
informal hearing, similar in nature to the hearing for debarments as 
discussed in 409.406-3(c).



Sec. 409.470  Appeals.

    A debarred or suspended contractor may appeal the debarring 
official's decision by mailing or otherwise furnishing a written notice 
within 90 days from the date of the decision to the U.S. Department of 
Agriculture Board of Contract Appeals, Washington, DC 20250. A copy of 
the notice of appeal shall be furnished to the debarring officer from 
whose decision the appeal is taken. Appeals under subpart 409.4 shall be 
governed by the rules and procedures of the U.S. Department of 
Agriculture Board of Contract Appeals set forth in 7 CFR part 24.

    Subpart 409.5_Organizational and Consultant Conflicts of Interest



Sec. 409.503  Waiver.

    (a) The HCA, on a non-delegable basis, is authorized to waive any 
general rule or procedure in FAR 9.5 when in the Government's interest.
    (b) Each request for waiver shall include:
    (1) The general rule or procedure proposed to be waived;
    (2) An analysis of the potential conflict, including the benefits 
and detriments to the Government and prospective contractors;

[[Page 108]]

    (3) A discussion of why the conflict cannot be avoided, neutralized, 
or mitigated; and
    (4) Advice of counsel obtained under FAR 9.504(b).

                           PART 410 [RESERVED]

                    PART 411_DESCRIBING AGENCY NEEDS

      Subpart 411.1_Selecting and Developing Requirements Documents

Sec.

Sec. 411.103  Market acceptance.

Sec. 411.105  Purchase descriptions for service contracts.

Sec. 411.170  Brand name or equal.

Sec. 411.171  Solicitation provisions and contract clauses.

       Subpart 411.2_Using and Maintaining Requirements Documents


Sec. 411.202  Maintenance of standardization documents.

             Subpart 411.4_Delivery or Performance Schedules


Sec. 411.404  Contract clauses.

                Subpart 411.6_Priorities and Allocations


Sec. 411.600  Scope of subpart.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

      Subpart 411.1_Selecting and Developing Requirements Documents



Sec. 411.103  Market acceptance.

    (a) The head of the contracting activity (HCA) may determine that 
offerors must demonstrate, in accordance with FAR 11.103(a), the market 
acceptability of their items to be offered.
    (b) The contracting officer shall place a copy of this 
determination, signed by the HCA, in the solicitation file.



Sec. 411.105  Purchase descriptions for service contracts.

    When contract personnel are to be used, the requiring official shall 
record on the requisition his or her determination whether harm to the 
Government might occur should contractor personnel fail to identify 
themselves as non-Government officials.



Sec. 411.170  Brand name or equal.

    (a) A ``brand name or equal'' purchase description shall include the 
following type of information:
    (1) Identification of the item by generic description.
    (2) Make, model number, catalog designation, or other description, 
and identification of a commercial catalog where it is listed.
    (3) Name of manufacturer, producer, or distributor of the item and 
complete address.
    (4) All salient characteristics of the ``brand name or equal'' 
product or products which have been determined by the requisitioner to 
be essential to the Government's minimum requirements.
    (b) [Reserved]



Sec. 411.171  Solicitation provisions and contract clauses.

    (a) Contracting officers shall insert the provision at 452.211-70, 
Brand Name or Equal, in solicitations, other than those for 
construction, where ``brand name or equal'' purchase descriptions are 
used.
    (b) Contracting officers shall insert the clause at 452.211-71, 
Equal Products Offered, in solicitations, other than those for 
construction, where the provision at 452.211-70 is included.
    (c) Contracting officers shall insert the clause at 452.211-72, 
Statement of Work/Specifications, when the description (statement of 
work) or specification(s) is included in Section J of the solicitation.
    (d) Contracting officers shall insert the clause at 452.211-73, 
Attachment to Statement of Work/Specifications, when there are 
attachments to the description (statement of work) or specifications.

[63 FR 26995, May 15, 1998]

[[Page 109]]

       Subpart 411.2_Using and Maintaining Requirements Documents



Sec. 411.202  Maintenance of standardization documents.

    Recommendations for changes to standardization documents are to be 
submitted through the Senior Procurement Executive, who will coordinate 
the submission of these recommendations to the cognizant preparing 
activity.

             Subpart 411.4_Delivery or Performance Schedules



Sec. 411.404  Contract clauses.

    (a) The contracting officer shall insert the clause at 452.211-74, 
Period of Performance, when it is necessary to specify a period of 
performance, beginning on the date of award, date of receipt of notice 
of award, or a specified date.
    (b) The contracting officer shall insert the clause at 452.211-75, 
Effective Period of the Contract, when it is necessary to specify the 
effective period of the contract.

[63 FR 26995, May 15, 1998]

                Subpart 411.6_Priorities and Allocations



Sec. 411.600  Scope of subpart.

    The Defense Priorities and Allocation System (DPAS) excludes USDA 
activities (see 15 CFR 700.18(b)). USDA Contracting Officers are not 
authorized to place rated orders under DPAS.

                PART 412_ACQUISITION OF COMMERCIAL ITEMS

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

   Subpart 412.3_Solicitation Provisions and Contract Clauses for the 
                     Acquisition of Commercial Items



Sec. 412.302  Tailoring of provisions and clauses for the acquisition of 
          commercial items.

    The head of the contracting activity is authorized to approve 
waivers in accordance with FAR 12.302(c). The approved waiver may be 
either for an individual contract or for a class of contracts for the 
specific item. The approved waiver and supporting documentation shall be 
incorporated into the contract file.

[61 FR 53646, Oct. 15, 1996]

[[Page 110]]



           SUBCHAPTER C_CONTRACTING METHODS AND CONTRACT TYPES

               PART 413_SIMPLIFIED ACQUISITION PROCEDURES

              Subpart 413.3_Simplified Acquisition Methods

Sec.

Sec. 413.301  Governmentwide commercial purchase card.

Sec. 413.306  SF 44, Purchase Order-Invoice-Voucher.

Sec. 413.307  Forms.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 64 FR 45895, Aug. 23, 1999, unless otherwise noted.

              Subpart 413.3_Simplified Acquisition Methods



Sec. 413.301  Governmentwide commercial purchase card.

    USDA policy and procedures on use of the Governmentwide commercial 
purchase card are established in Departmental Regulation Series 5000.



Sec. 413.306  SF 44, Purchase Order-Invoice-Voucher.

    The Standard Form 44 (and the previously prescribed USDA Form AD-
744) is not authorized for use within USDA.



Sec. 413.307  Forms.

    Form AD-838, Purchase Order, is prescribed for use by USDA in lieu 
of Optional Forms 347 and 348.

                         PART 414_SEALED BIDDING

                   Subpart 414.2_Solicitation of Bids

Sec.

Sec. 414.201  Preparation of invitations for bids.

Sec. 414.201-6  Solicitation provision.

           Subpart 414.4_Opening of Bids and Award of Contract


Sec. 414.404  Rejection of bids.

Sec. 414.404-1  Cancellation of invitations after opening.

Sec. 414.407  Mistakes in bids.

Sec. 414.407-3  Other mistakes disclosed before award.

Sec. 414.407-4  Mistakes after award.

Sec. 414.409  Information to bidders.

Sec. 414.409-2  Award of classified contracts.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                   Subpart 414.2_Solicitation of Bids



Sec. 414.201  Preparation of invitations for bids.



Sec. 414.201-6  Solicitation provision.

    The contracting officer shall insert the provision 452.214-70, Award 
by Lot, when multiple items are segregated into clearly identifiable 
lots and the contracting officer wants to reserve the right to award by 
item within a lot, if award in that manner would be advantageous to the 
Government.

           Subpart 414.4_Opening of Bids and Award of Contract



Sec. 414.404  Rejection of bids.



Sec. 414.404-1  Cancellation of invitations after opening.

    An acquisition official at a level above the contracting officer is 
authorized to make the determinations under FAR 14.404-1(c) and (e)(1).



Sec. 414.407  Mistakes in bids.



Sec. 414.407-3  Other mistakes disclosed before award.

    The authority to make the determinations under FAR 14.407-3(a), (b), 
and (d) is delegated, without power of redelegation, to the head of the 
contracting activity. The authority to make the determination under FAR 
14.407-3(c) is delegated to the contracting officer. Each determination 
pursuant to FAR 14.407-3 shall have the concurrence of the Office of the 
General Counsel (OGC).



Sec. 414.407-4  Mistakes after award.

    If a mistake in bid is disclosed after award, the contracting 
officer shall

[[Page 111]]

make a final determination in accordance with the provisions of FAR 
14.407-4 (b) and (c) and shall coordinate each proposed determination 
with OGC. Such coordination shall, at a minimum, consist of the 
contracting officer providing the proposed determination and the case 
file to OGC for comment.



Sec. 414.409  Information to bidders.



Sec. 414.409-2  Award of classified contracts.

    Disposition of classified information shall be in accordance with 
Departmental Regulation and Manual (3400 Series) and in accordance with 
direction issued by the USDA Security Officer, Policy Analysis and 
Coordination Center--Human Resources Management.

                   PART 415_CONTRACTING BY NEGOTIATION

   Subpart 415.2_Solicitation and Receipt of Proposals and Information

Sec.

Sec. 415.204  Contract format.

Sec. 415.207  Handling proposals and information.

Sec. 415.209  Solicitation provisions and contract clauses.

                     Subpart 415.3_Source Selection


Sec. 415.303  Responsibilities.

Sec. 415.305  Proposal evaluation.

                     Subpart 415.4_Contract Pricing


Sec. 415.404-4  Profit.

Subpart 415.5_Preaward, Award, and Postaward Notifications, Protests and 
                                Mistakes


Sec. 415.570  Post-award conference.

                   Subpart 415.6_Unsolicited Proposals


Sec. 415.604  Agency points of contact.

Sec. 415.606  Agency procedures.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 64 FR 52674, Sept. 30, 1999, unless otherwise noted.

   Subpart 415.2_Solicitation and Receipt of Proposals and Information



Sec. 415.204  Contract format.

    The Senior Procurement Executive is authorized to exempt contracts 
from the uniform contract format.



Sec. 415.207  Handling proposals and information.

    (a) Throughout the source selection process, agency personnel and 
non-Government evaluators with access to proposal information shall 
disclose neither the number of offerors nor their identity except as 
authorized by FAR subpart 15.5. (See also FAR 5.403.)
    (b) The contracting officer shall obtain the following written 
agreement from the non-Government evaluator prior to the release of any 
proposal to that evaluator.

         AGREEMENT GOVERNING THE USE AND DISCLOSURE OF PROPOSALS

RFP_____________________________________________________________________
Offeror_________________________________________________________________
    1. To the best of my knowledge and belief, no conflict of interest 
exists that may diminish my capacity to perform an impartial and 
objective review of the offeror's proposal, or may otherwise result in a 
biased opinion or an unfair advantage. If a potential conflict of 
interest arises or if I identify such a conflict, I agree to notify the 
Government promptly concerning the potential conflict. In determining 
whether any potential conflict of interest exists, I agree to review 
whether my or my employer's relationships with other persons or 
entities, including, but not limited to, ownership of stocks, bonds, 
other outstanding financial interests or commitments, employment 
arrangements (past, present, or under consideration), and, to the extent 
known by me, all financial interests and employment arrangements of my 
spouse, minor children, and other members of my immediate household, may 
place me in a position of conflict, real or apparent, with the 
evaluation proceedings.
    2. I agree to use proposal information only for evaluation purposes. 
I understand that any authorized restriction on disclosure placed upon 
the proposal by the prospective contractor or subcontractor or by the 
Government shall be applied to any reproduction or abstracted 
information of the proposal. I agree to use my best effort to safeguard 
such information physically, and not to disclose the contents of, or 
release any information

[[Page 112]]

relating to, the proposal(s) to anyone outside of the Source Evaluation 
Board or other panel assembled for this acquisition, the Contracting 
Officer, or other individuals designated by the Contracting Officer.
    3. I agree to return to the Government all copies of proposals, as 
well as any abstracts, upon completion of the evaluation.
_______________________________________________________________________
(Name and Organization)
_______________________________________________________________________
(Date)

                           (End of provision)

    (c) The release of a proposal to a non-Government evaluator for 
evaluation does not constitute the release of information for purposes 
of the Freedom of Information Act (5 U.S.C. 552).
    (d) The contracting officer shall attach a cover page bearing the 
following notice: GOVERNMENT NOTICE FOR HANDLING PROPOSALS--This 
proposal shall be used and disclosed for evaluation purposes only. 
Attach a copy of this Government notice to every reproduction or 
abstract of the proposal. Any authorized restrictive notices which the 
submitter places on this proposal shall be strictly complied with. 
Disclosure of this proposal outside the Government for evaluation 
purposes shall be made only to the extent authorized by, and in 
accordance with, FAR 3.104-5, FAR 15.207, and AGAR 415.207.

[64 FR 52674, Sept. 30, 1999; 64 FR 54963, Oct. 8, 1999]



Sec. 415.209  Solicitation provisions and contract clauses.

    (a) The provision at 452.215-71, Instructions for the Preparation of 
Technical and Business Proposals, may be used when offerors will be 
required to submit technical and business proposals. Contracting 
officers should tailor the clause to reflect the degree of information 
required for the specific acquisition.
    (b) The contracting officer shall insert the provision at 452.215-
72, Amendments to Proposals, in solicitations which require the 
submittal of lengthy, complex technical proposals.

                     Subpart 415.3_Source Selection



Sec. 415.303  Responsibilities.

    The head of the contracting activity (HCA) is authorized to appoint 
an individual other than the contracting officer as the source selection 
authority.



Sec. 415.305  Proposal evaluation.

    HCAs are responsible for establishing procedures regarding the 
release of cost information to the members of the technical evaluation 
team.

                     Subpart 415.4_Contract Pricing



Sec. 415.404-4  Profit.

    (a)(1) USDA will use a structured approach to determine the profit 
or fee prenegotiation objective in acquisition actions when price 
negotiation is based on cost analysis.
    (2) The following types of acquisitions are exempt from the 
requirements of the structured approach, but the contracting officer 
shall comply with FAR 15.404-4(d) when analyzing profit for these 
contracts or actions:
    (i) Architect-engineer contracts;
    (ii) Construction contracts;
    (iii) Contracts primarily requiring delivery of material supplied by 
subcontractors;
    (iv) Termination settlements; and
    (v) Cost-plus-award-fee contracts;
    (b) Unless otherwise restricted by contracting activity procedures, 
the Contracting Officer may use another Federal agency's structured 
approach if that approach has been formalized and is maintained as part 
of that Agency's acquisition regulations (i.e., included in that 
Agency's assigned chapter of Title 48 of the Code of Federal 
Regulations).
    (c) The HCA is responsible for establishing procedures to ensure 
compliance with this subpart.

[[Page 113]]

Subpart 415.5_Preaward, Award, and Postaward Notifications, Protests and 
                                Mistakes



Sec. 415.570  Post-award conference.

    If a postaward conference is necessary, the contracting officer 
shall insert clause 452.215-73, Post-Award Conference.

                   Subpart 415.6_Unsolicited Proposals



Sec. 415.604  Agency points of contact.

    HCAs are responsible for establishing procedures to ensure 
compliance with the requirements of FAR 15.604.



Sec. 415.606  Agency procedures.

    HCAs are responsible for establishing the procedures for control of 
unsolicited proposals required by FAR 15.606(a) and for identifying the 
contact points as required by FAR 15.606(b).

                       PART 416_TYPES OF CONTRACTS

Sec.

Sec. 416.000  Scope of part.

                   Subpart 416.2_Fixed-Price Contracts


Sec. 416.203  Fixed-price contracts with economic price adjustment.

Sec. 416.203-4  Contract clauses.

                    Subpart 416.4_Incentive Contracts


Sec. 416.405  Cost-reimbursement incentive contracts.

Sec. 416.405-2  Cost-plus-award-fee contracts.

Sec. 416.406  Contract clauses.

Sec. 416.470  Solicitation provision.

               Subpart 416.5_Indefinite-Delivery Contracts


Sec. 416.505  Ordering.

Sec. 416.506  Solicitation provision and contract clauses.

   Subpart 416.6_Time-and-Materials, Labor-Hour, and Letter Contracts


Sec. 416.603  Letter contracts.

Sec. 416.603-2  Application.

Sec. 416.603-4  Contract clauses.

Sec. 416.670  Contract clauses.

                        Subpart 416.7_Agreements


Sec. 416.702  Basic agreements.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.



Sec. 416.000  Scope of part.

    Heads of contracting activities (HCA's) are authorized to establish 
written procedures allowing the use of any contract type described in 
FAR part 16 for acquisitions made under simplified acquisition 
procedures in FAR part 13.

                   Subpart 416.2_Fixed-Price Contracts



Sec. 416.203  Fixed-price contracts with economic price adjustment.



Sec. 416.203-4  Contract clauses.

    An economic price adjustment clause based on cost indexes of labor 
or material may be used under the conditions listed in FAR 16.203-4(d) 
after approval by the HCA and consultation with the Office of the 
General Counsel.

                    Subpart 416.4_Incentive Contracts



Sec. 416.405  Cost-reimbursement incentive contracts.



Sec. 416.405-2  Cost-plus-award-fee contracts.

    The HCA may designate an acquisition official other than the 
contracting officer as the fee determination official (FDO) to make the 
final determination of the award fee. The designated official must have 
warranted contracting authority at the same level as the contracting 
officer or higher, and shall not have participated in preparing the 
contractor performance evaluation. If the HCA does not designate an FDO, 
the chief of the contracting office shall act as the FDO.

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26995, May 15, 1998.]



Sec. 416.406  Contract clauses.

    The contracting officer shall insert a clause substantially the same 
as the

[[Page 114]]

clause at 452.216-70, Award Fee, in solicitations and contracts which 
contemplate the award of cost-plus-award-fee contracts.

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26995, May 15, 1998.]



Sec. 416.470  Solicitation provision.

    The contracting officer shall insert the provision at 452.216-71, 
Base Fee and Award Fee Proposal, in solicitations which contemplate the 
award of a cost-plus-award-fee contract.

               Subpart 416.5_Indefinite-Delivery Contracts



Sec. 416.505  Ordering.

    (a) The Chief, Procurement Policy Division, Procurement and Property 
Management, Policy Analysis and Coordination Center, has been designated 
as the Departmental Task Order Ombudsman.
    (b) The Departmental Task Order Ombudsman shall designate a task 
order ombudsman for each contracting activity. Contracting activity 
ombudsmen shall review and resolve complaints from contractors 
concerning task or delivery orders placed by the contracting activity.
    (c) Any contractor who is not satisfied with the resolution of a 
complaint by a contracting activity ombudsman may request the 
Departmental Task Order Ombudsman to review the complaint.



Sec. 416.506  Solicitation provision and contract clauses.

    (a) The contracting officer shall insert a provision substantially 
the same as the provision at 452.216-72, Evaluation Quantities-
Indefinite-Delivery Contract, in solicitations which contemplate the 
award of indefinite-quantity or requirements contracts to establish the 
basis on which offers will be evaluated.
    (b) The contracting officer shall insert the clause at 452.216-73, 
Minimum and Maximum Contract Amounts, in indefinite-delivery, 
indefinite-quantity contracts when the clause at FAR 52.216-18 is used.

   Subpart 416.6_Time-and-Materials, Labor-Hour, and Letter Contracts



Sec. 416.603  Letter contracts.



Sec. 416.603-2  Application.

    The HCA is authorized to extend the period for defining a letter 
contract required by FAR 16.603-2(c) in extreme cases where it is 
determined in writing that such action is in the best interest of the 
Government.



Sec. 416.603-4  Contract clauses.

    The contracting officer shall insert the clause at 452.216-75, 
Letter Contract, in a definitive contract superseding a letter contract.



Sec. 416.670  Contract clauses.

    The contracting officer shall limit the Government's obligation 
under a time-and-materials or labor-hour contract by inserting the 
clause at 452.216-74, Ceiling Price.

                        Subpart 416.7_Agreements



Sec. 416.702  Basic agreements.

    Promptly after execution by the Government, the HCA shall furnish to 
the Senior Procurement Executive a copy of each basic agreement 
negotiated with contractors in accordance with FAR 16.702.

                  PART 417_SPECIAL CONTRACTING METHODS

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

                          Subpart 417.2_Options



Sec. 417.204  Contracts.

    The head of the contracting activity is authorized to approve 
contracts which exceed the 5 year limitation in FAR 17.204(e).

[61 FR 53646, Oct. 15, 1996]

                           PART 418 [RESERVED]

[[Page 115]]



                   SUBCHAPTER D_SOCIOECONOMIC PROGRAMS

                    PART 419_SMALL BUSINESS PROGRAMS

                         Subpart 419.2_Policies

Sec.

Sec. 419.201  General policy.

Sec. 419.201-70  Office of Small and Disadvantaged Business Utilization 
          (OSDBU).

Sec. 419.201-71  Small business coordinators.

Sec. 419.201-73  Reports.

               Subpart 419.5_Set-Asides for Small Business


Sec. 419.508  Solicitation provisions.

     Subpart 419.6_Certificates of Competency and Determinations of 
                               Eligibility


Sec. 419.602  Procedures.

Sec. 419.602-1  Referral.

Sec. 419.602-3  Resolving differences between the agency and the Small 
          Business Administration.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                         Subpart 419.2_Policies



Sec. 419.201  General policy.

    It is the policy of USDA to provide a fair portion of its 
contracting and subcontracting opportunities to small, disadvantaged, 
minority, and women-owned businesses.



Sec. 419.201-70  Office of Small and Disadvantaged Business Utilization 
          (OSDBU).

    The Office of Small and Disadvantaged Business Utilization (OSDBU) 
develops rules, policy, procedures and guidelines for the effective 
administration of USDA's small and disadvantaged business procurement 
preference program to include minority and women-owned business.



Sec. 419.201-71  Small business coordinators.

    The head of the contracting activity (HCA) or a representative of 
the HCA shall designate in writing a small business coordinator in each 
contracting office. Supervisors of small business coordinators are 
encouraged to provide sufficient time for the coordinators to carry out 
their small business program duties. Coordinators' duties shall include, 
but not be limited to, the following:
    (a) Review each proposed acquisition expected to exceed the 
simplified acquisition threshold prior to its solicitation. The 
coordinator shall:
    (1) Recommend section 8(a) action and identify potential 
contractors, or
    (2) Identify available minority and women-owned businesses to be 
solicited by competitive procedures. Coordinators shall document the 
contract file with recommendations made and actions taken.
    (b) Participate in goal-setting procedures and planning activities 
and establish aggressive minority and women-owned business goals based 
on the annual review of advance acquisition plans.
    (c) Participate in the review of those contracts which require the 
successful offeror to submit written plans for the utilization of small 
and small disadvantaged businesses as subcontractors.
    (d) Ensure that purchases exceeding $2,500 and not exceeding the 
simplified acquisition threshold are reserved exclusively for small 
businesses, including minority and women-owned businesses. This policy 
shall be implemented unless the contracting officer is unable to obtain 
offers from two or more small business concerns that are competitive 
with market prices and in terms of quality and delivery of the goods or 
services being purchased.
    (e) Maintain comprehensive source listings of small businesses.
    (f) Upon written request, provide small, minority and women-owned 
businesses the bidders mailing lists of individuals receiving 
solicitations which will contain the subcontracting clause entitled 
``Utilization of Small Business Concerns and Small Disadvantaged 
Business Concerns.'' These lists may be limited to those supplies or 
services of major interest to the requesting firms.

[[Page 116]]

    (g) Develop a program of contacts with local, small, minority, and 
women-owned trade, business, and professional associations and 
organizations and Indian tribal councils to apprise them of USDA's 
program needs and recurring contract requirements.
    (h) Periodically meet with program managers to discuss requirements 
of the small business preference program, explore the feasibility of 
breaking large complex requirements into smaller lots suitable for 
participation by small firms, and encourage program managers to meet 
with these firms so that their capabilities can be demonstrated.
    (i) Establish internal operating procedures which implement the 
requirements of the regulations as set forth in this part 419. Compile 
data and prepare all reports pertaining to the small, minority and 
women-owned business activities. Ensure that these reports are accurate, 
complete and up-to-date.
    (j) Assist and counsel small business firms and especially those 
found to be nonresponsive or nonresponsible to help qualify them for 
future awards.
    (k) Review proposed large contract requirements to determine the 
potential for breaking out components suitable for purchase from small 
business firms.
    (l) Ensure that the SBA Resident Procurement Center Representative 
(PCR) is provided an opportunity and reasonable time to review any 
solicitation that meets the dollar threshold for small business and 
small disadvantaged business subcontracting plans.



Sec. 419.201-73  Reports.

    (a) The Director, OSDBU, shall be responsible for submitting reports 
concerning USDA's progress and achievements in the procurement 
preference program.
    (b) The following dates must be adhered to in regard to the 
reporting of subcontract award data.


Sec. SF-294 Reports
    Frequency: Twice a Year.
    Cut-off date (Reporting Period Ending): March 31.
    Date Due at Contracting Activity: April 30.
    Cut-off date (Reporting Period Ending): September 30.
    Date Due at Contracting Activity: October 30.

Sec. SF-295 Reports
    Frequency: Once a Year.
    Cut-off date (12 Month-Period Ending): September 30.
    Date Due at OSDBU: October 30.

[61 FR 53646, Oct. 15, 1996, as amended at 63 FR 26995, May 15, 1998]

               Subpart 419.5_Set-Asides for Small Business



Sec. 419.508  Solicitation provisions.

    The contracting officer shall insert the provision at 452.219-70, 
Size Standard and SIC Code Information, in solicitations that are set 
aside for small businesses.

    Effective Date Note: At 66 FR 49317, Sept. 27, 2001, Sec. 419.508 
was amended by removing the acronym ``SIC'' and adding, in its place, 
the acronym ``NAICS'', effective Nov. 26, 2001.

     Subpart 419.6_Certificates of Competency and Determinations of 
                               Eligibility



Sec. 419.602  Procedures.



Sec. 419.602-1  Referral.

    Contracting officers shall refer determinations of non-
responsibility regarding small businesses directly to the SBA Regional 
Office servicing the location where the contractor's office (home) is 
located.



Sec. 419.602-3  Resolving differences between the agency and the Small 
          Business Administration.

    The HCA is authorized to appeal the issuance of a COC to SBA 
Headquarters as provided by FAR 19.602-3(a).

[63 FR 26995, May 15, 1998]

                        PARTS 420	421 [RESERVED]

      PART 422_APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITIONS

                   Subpart 422.1_Basic Labor Policies

Sec.

Sec. 422.103  Overtime.

Sec. 422.103-4  Approvals.

[[Page 117]]

       Subpart 422.3_Contract Work Hours and Safety Standards Act


Sec. 422.302  Liquidated damages and overtime pay.

   Subpart 422.4_Labor Standards for Contracts Involving Construction


Sec. 422.404  Davis-Bacon Act wage determinations.

Sec. 422.404-6  Modifications of wage determinations.

Sec. 422.406  Administration and enforcement.

Sec. 422.406-8  Investigations.

             Subpart 422.6_Walsh-Healey Public Contracts Act


Sec. 422.604  Exemptions.

Sec. 422.604-2  Regulatory exemptions.

Sec. 422.608  [Reserved]

               Subpart 422.8_Equal Employment Opportunity


Sec. 422.803  Responsibilities.

Sec. 422.804  Affirmative action programs.

Sec. 422.804-2  Construction.

Sec. 422.807  Exemptions.

        Subpart 422.13_Special Disabled and Vietnam Era Veterans


Sec. 422.1303  Waivers.

Sec. 422.1306  Complaint procedures.

              Subpart 422.14_Employment of the Handicapped


Sec. 422.1403  Waivers.

Sec. 422.1406  Complaint procedures.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                   Subpart 422.1_Basic Labor Policies



Sec. 422.103  Overtime.



Sec. 422.103-4  Approvals.

    Requests for the use of overtime shall be approved by an acquisition 
official at a level above the contracting officer in accordance with the 
procedures in FAR 22.103-4 (a) and (b).

       Subpart 422.3_Contract Work Hours and Safety Standards Act



Sec. 422.302  Liquidated damages and overtime pay.

    Heads of contracting activities (HCA's) are authorized to review 
determinations of liquidated damages due under section 104(c) of the 
Contract Work Hours and Safety Standards Act, and to take remedial 
action, if appropriate, in accordance with FAR 22.302(c). Contractors or 
subcontractors may request review of administrative determinations of 
liquidated damages by written notice to the contracting officer. The 
contracting officer shall promptly forward appeals of liquidated damages 
determinations to the HCA.

   Subpart 422.4_Labor Standards for Contracts Involving Construction



Sec. 422.404  Davis-Bacon Act wage determinations.



Sec. 422.404-6  Modifications of wage determinations.

    HCA's are authorized to request extension of the 90 day period for 
award after bid opening as provided in FAR 22.404-6(b)(6).



Sec. 422.406  Administration and enforcement.



Sec. 422.406.8  Investigations.

    Reports of violations shall be forwarded to the HCA, who shall 
process such reports in accordance with FAR 22.406-8(d).

             Subpart 422.6_Walsh-Healey Public Contracts Act



Sec. 422.604  Exemptions.



Sec. 422.604-2  Regulatory exemptions.

    The Assistant Secretary for Administration can request the Secretary 
of labor to exempt contracts from the Walsh-Healey Public Contracts Act 
pursuant to FAR 22.604-2(c). A written

[[Page 118]]

finding justifying the request for exemption shall be prepared for the 
Assistant Secretary's signature and submitted by the HCA to the Senior 
Procurement Executive (SPE) for referral to the Assistant Secretary.



Sec. 422.608  [Reserved]

               Subpart 422.8_Equal Employment Opportunity



Sec. 422.803  Responsibilities.

    The contracting office shall submit questions involving the 
applicability of Executive Order 11246 and FAR subpart 22.8 through the 
HCA to the SPE for resolution.



Sec. 422.804  Affirmative action programs.



Sec. 422.804-2  Construction.

    The HCA shall ensure that each contracting office, awarding 
nonexempt construction contracts, maintains a current listing of covered 
geographical areas subject to affirmative action requirements specifying 
goals for minorities and women in covered construction trades.



Sec. 422.807  Exemptions.

    (a) The Assistant Secretary for Administration is authorized to make 
the determination in FAR 22.807(a)(1) that a contract is essential to 
the national security.
    (b) The contracting officer shall submit requests for exemptions 
under FAR 22.807(a)(1), (a)(2), and (b)(5) through the HCA to the SPE 
for determination by the Assistant Secretary of Administration or 
referral to the Director, Office of Federal Contract Compliance Programs 
(OFCCP), as appropriate.

        Subpart 422.13_Special Disabled and Vietnam Era Veterans



Sec. 422.1303  Waivers.

    (a) The Assistant Secretary for Administration is authorized to make 
the waiver determinations under FAR 22.1303(a) and FAR 22.1303(b) with 
concurrence of the Director, OFCCP.
    (b) The contracting office shall submit requests for waivers through 
the HCA to the SPE for determination by the Assistant Secretary for 
Administration.



Sec. 422.1306  Complaint procedures.

    The contracting officer shall forward complaints received about the 
administration of the Vietnam Era Veterans Readjustment Assistance Act 
directly to the Department of Labor (DoL) as prescribed in FAR 22.1306.

              Subpart 422.14_Employment of the Handicapped



Sec. 422.1403  Waivers.

    (a) The Assistant Secretary for Administration is authorized to make 
the waiver determinations under FAR 22.1403(a) and (b) with concurrence 
of the Director, OFCCP.
    (b) The contracting officer shall submit requests for waivers 
through the HCA to the SPE for determination by the Assistant Secretary 
for Administration.



Sec. 422.1406  Complaint procedures.

    The contracting officer shall forward complaints received about the 
administration of Section 503 of the Rehabilitation Act of 1973, as 
amended, directly to the OFCCP as prescribed in FAR 22.1406.

 PART 423_ENVIRONMENT, CONSERVATION, OCCUPATIONAL SAFETY, AND DRUG-FREE 
                                WORKPLACE

         Subpart 423.1_Pollution Control and Clean Air and Water

Sec.

Sec. 423.101  Applicability.

Sec. 423.103  Policy.

Sec. 423.104  Exemptions.

Sec. 423.106  Delaying award.

Sec. 423.107  Compliance responsibilities.

                    Subpart 423.2_Energy Conservation


Sec. 423.203  Policy.

                Subpart 423.4_Use of Recovered Materials


Sec. 423.400  Scope of subpart.

Sec. 423.402  Definitions.

Sec. 423.404  Procedures.

Sec. 423.404-70  Acquisition, Recycling, and Waste Prevention Program 
          (AR&WPP).

[[Page 119]]

                    Subpart 423.5_Drug-Free Workplace


Sec. 423.506  Suspension of payments, termination of contract, and 
          debarment and suspension actions.

              Subpart 423.6_Notice of Radioactive Material


Sec. 423.601  Requirements.

  Subpart 423.7_Contracting for Environmentally Preferable and Energy-
                     Efficient Products and Services


Sec. 423.704  Policy.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

         Subpart 423.1_Pollution Control and Clean Air and Water



Sec. 423.101  Applicability.

    In addition to the requirement in FAR 23.101, this subpart applies 
to indefinite-delivery contracts, other than those for commercial items, 
when the contracting officer estimates that the contract will exceed 
$100.000.



Sec. 423.103  Policy.

    The head of the contracting activity (HCA) shall establish a system 
of instructions to make available to each contracting officer the EPA 
List of Violating Facilities and to ensure the contracting officer 
reviews the list prior to each proposed award.



Sec. 423.104  Exemptions.

    (a) The Assistant Secretary for Administration is authorized to 
grant an exemption described in FAR 23.104.
    (b) The Senior Procurement Executive (SPE) is authorized to consult 
with the EPA Administrator regarding a proposed class exemption.



Sec. 423.106  Delaying award.

    Prior to notifying EPA, the contracting officer shall advise the SPE 
of the need to award before the requested time period expires.



Sec. 423.107  Compliance responsibilities.

    The HCA is authorized to notify the Administrator of EPA of known or 
suspected noncompliance with clean air or water standards in facilities 
used in performing nonexempt contracts. A copy of the notification is to 
be provided to the SPE.

                    Subpart 423.2_Energy Conservation



Sec. 423.203  Policy.

    In the acquisition of products and services, USDA will give 
preference to those that are more energy-efficient.

                Subpart 423.4_Use of Recovered Materials



Sec. 423.400  Scope of subpart.

    This subpart implements and supplements FAR policies and procedures 
for acquiring products and services when preference is given to offers 
of products containing recovered materials. This subpart further 
supplements FAR subpart 23.4 by providing guidance for recycling and 
waste prevention programs in accordance with Executive Order 12873 and 
42 U.S.C. 6962.



Sec. 423.402  Definitions.

    Mission areas are USDA organizational elements headed by an 
Undersecretary or an Assistant Secretary.
    USDA Acquisition, Recycling, and Waste Prevention Program, issued by 
the USDA Environmental Executive, provides implementing guidance for 
Departmental affirmative procurement, recycling, and waste reduction.
    The USDA Environmental Executive is the Deputy Assistant Secretary 
for Administration.



Sec. 423.404  Procedures.

    (a) The dollar thresholds described in FAR 23.404(a) apply to USDA 
as a whole.
    (b) EPA designated items. The officials identified as Acquisition, 
Recycling, and Waste Prevention Program (AR&WPP) Coordinators are 
authorized to approve determinations to buy EPA designated items which 
do not meet EPA or USDA minimum recovered material content standards.
    (c) Agency designated items. The USDA Environmental Executive may, 
without further publication in this chapter,

[[Page 120]]

designate items or classes of items containing recovered material to be 
acquired under the procedures in FAR 23.4 and this subpart.



Sec. 423.404-70  Acquisition, Recycling, and Waste Prevention Program 
          (AR&WPP).

    (a) Applicability. The AR&WPP applies to all USDA organizations; 
i.e., USDA mission areas, USDA corporations (as described in 31 U.S.C. 
9101), and USDA staff offices not included within a mission area.
    (b) Authority. The AR&WPP has been established to comply with the 
requirements of Executive Order 12873 to coordinate all environmental 
programs in the areas of procurement and acquisition, standards and 
specification review, facilities management, waste prevention and 
recycling, and logistics.
    (c) Responsibilities. (1) Each USDA organization will identify one 
or more AR&WPP Coordinators in writing to represent the mission area, 
serve on the Council of Coordinators, and work in conjunction with the 
USDA Environmental Executive.
    (2) Each USDA organization periodically will conduct an audit 
(survey or inventory) of the waste stream generated by the organization. 
The goals of the audit are:
    (i) To identify and measure the elements of waste generated in its 
operations;
    (ii) To identify processes, equipment, techniques, or materials 
which generate waste in energy or materials;
    (iii) To identify actions which can be taken to reduce and to 
recycle or recover the wastes generated; and
    (iv) To assign time frames to accomplish those actions.
    (3) Each USDA organization will implement an avoidance or recovery 
or recycling program based on the results of the waste stream audit.
    (4) Each USDA organization will implement a plan to install on-going 
waste prevention techniques.
    (5) Each USDA organization will ensure that responsibility for 
preparation, implementation, and monitoring of its affirmative 
procurement program is shared between program personnel and procurement 
personnel.
    (6) Each USDA organization will establish measurable goals by which 
the effectiveness of its participation in AR&WPP can be assessed on an 
annual basis.
    (7) Each USDA organization will sponsor annual awards to recognize 
the most innovative environmental program of the year.
    (d) Acquisition and administration. (1) Each USDA organization will 
annually review its product descriptions to enhance the use of recovered 
materials and environmentally preferable products and services by 
eliminating from the product description:
    (i) Any exclusion of recovered materials, and
    (ii) Any requirement that items be manufactured from virgin 
materials.
    (2) Each USDA organization will create a promotion program to 
internally and externally promote its desire to buy recycled products.
    (3) Each USDA organization will implement the USDA electronic 
acquisition system to reduce waste by eliminating unnecessary paper 
transactions and to foster accurate data collection and reporting of 
acquisitions.
    (4) Each USDA organization will establish an affirmative procurement 
program specifically for the needs and requirements of its own 
organization, to maximize environmental benefits, consistent with price, 
performance, and availability considerations.
    (5) Each USDA organization will ensure that the on-going inspection 
and production surveillance systems in place will monitor the production 
or the testing of goods and services to verify the recovered material 
contents reported.
    (6) Each USDA organization will include
    (i) Requirements in contracts for contractor operation of 
Government-owned or leased facilities to provide for waste prevention 
activities and the recycling of materials and
    (ii) Environmental and recycling factors in the selection process 
for the acquisition and management of real property.

[[Page 121]]

                    Subpart 423.5_Drug-Free Workplace



Sec. 423.506  Suspension of payments, termination of contract, and 
          debarment and suspension actions.

    (a) The contracting officer may recommend waiver of the 
determination to suspend payments, to terminate a contract, or to debar 
or to suspend a contractor.
    (b) The recommendation shall be submitted through the HCA to the SPE 
and shall include a full description of the disruption of USDA 
operations should the determination not be waived.
    (c) The SPE will submit the request for a waiver to the Secretary 
with a recommendation for action.

              Subpart 423.6_Notice of Radioactive Material



Sec. 423.601  Requirements.

    The HCA shall establish a system of instructions to identify the 
installation/facility radiation protection officer.

  Subpart 423.7_Contracting for Environmentally Preferable and Energy-
                     Efficient Products and Services



Sec. 423.704  Policy.

    In its acquisitions, USDA will give preference to environmentally 
preferable and energy-efficient products and services.

        PART 424_PROTECTION OF PRIVACY AND FREEDOM OF INFORMATION

             Subpart 424.1_Protection of Individual Privacy

Sec.

Sec. 424.103  Procedures.

Sec. 424.104  Contract clauses.

                Subpart 424.2_Freedom of Information Act


Sec. 424.203  Policy.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

             Subpart 424.1_Protection of Individual Privacy



Sec. 424.103  Procedures.

    USDA regulations implementing the Privacy Act are found in 7 CFR, 
subtitle A, part 1, subpart G. Contracting officers shall follow these 
regulations when responding to requests for information or awarding 
contracts that will involve the design, development, or operation of a 
system of records on individuals to accomplish agency functions.



Sec. 424.104  Contract clauses.

    When applicable, the contracting officer shall insert the clause at 
452.224-70, Confidentiality of Information, in contracts involving 
confidential information.

                Subpart 424.2_Freedom of Information Act



Sec. 424.203  Policy.

    USDA regulations implementing the Freedom of Information Act are 
found in 7 CFR, subtitle A, part 1, subpart A. Contracting officers 
shall follow these regulations when responding to requests for 
information or awarding contracts that will involve the design, 
development, or operation of a system of records on individuals to 
accomplish agency functions.

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26995, May 15, 1998.]

                      PART 425_FOREIGN ACQUISITION

                 Subpart 425.1_Buy American Act_Supplies

Sec.

Sec. 425.102  Policy.

Sec. 425.105  Evaluating offers.

Sec. 425.108  Expected articles, materials, and supplies.

          Subpart 425.2_Buy American Act_Construction Materials


Sec. 425.202  Policy.

Sec. 425.203-425.204  [Reserved]

[[Page 122]]

                Subpart 425.3_Balance of Payments Program


Sec. 425.302  Policy.

Sec. 425.304  Excess and near-excess foreign currencies.

                     Subpart 425.4_Trade Agreements


Sec. 425.402  Policy.

          Subpart 425.9_Additional Foreign Acquisition Clauses


Sec. 425.901  Omission of audit clause.

   Subpart 425.10_Implementation of Sanctions Against Countries That 
 Discriminate Against United States Products or Services in Government 
                               Procurement


Sec. 425.1002  Trade sanctions.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                 Subpart 425.1_Buy American Act_Supplies



Sec. 425.102  Policy.

    The Senior Procurement Executive (SPE) shall make the determination 
prescribed in FAR 25.102(a)(3).



Sec. 425.105  Evaluating offers.

    The SPE shall make the determinations prescribed in FAR 25.105. 
Requests for SPE approval shall be submitted by the HCA, in writing, and 
shall provide a detailed justification supporting why the proposed award 
is in the best interest of the Government.



Sec. 425.108  Excepted articles, materials, and supplies.

    (a) Copies of determinations of nonavailability in accordance with 
FAR 25.102(a)(4) or 25.202(a)(3), for articles, material or supplies not 
listed in FAR 25.108, shall be submitted to the SPE for submission to 
the FAR Council.
    (b) Information required by FAR 25.108(c) shall be submitted to the 
SPE for submission to the FAR Council.

          Subpart 425.2_Buy American Act_Construction Materials



Sec. 425.202  Policy.

    (a) The SPE shall make the determination prescribed in FAR 
25.202(a)(3).
    (b) If a contracting officer proposes that the use of a particular 
domestic construction material should be waived for a contract on the 
grounds that its use would be impracticable, the contracting officer 
shall submit a proposed determination with supporting information 
through the HCA to the SPE for approval or disapproval.

[63 FR 26995, May 15, 1998]



Sec. 425.203-425.204  [Reserved]

                Subpart 425.3_Balance of Payments Program



Sec. 425.302  Policy.

    The HCA shall make the determinations prescribed in FAR 25.302(b)(2) 
and (3) and may authorize differentials greater than 50 percent as 
prescribed in FAR 25.302(c).



Sec. 425.304  Excess and near-excess foreign currencies.

    HCA's shall make the determinations as to the feasibility of using 
excess or near-excess currency.

                     Subpart 425.4_Trade Agreements



Sec. 425.402  Policy.

    Whenever the U.S. Trade Representative publishes a redetermination 
of the dollar threshold at which the Trade Agreements Act applies, that 
dollar threshold will be published in a Departmental Notice, 5025 
series.

          Subpart 425.9_Additional Foreign Acquisition Clauses



Sec. 425.901  Omission of audit clause.

    The SPE shall make the determination under FAR 25.901(c)(1).

[[Page 123]]

   Subpart 425.10_Implementation of Sanctions Against Countries That 
 Discriminate Against United States Products or Services in Government 
                               Procurement



Sec. 425.1002  Trade sanctions.

    The Secretary, without power of redelegation, has the authority to 
make the necessary determination(s) and authorize award(s) of 
contract(s) in accordance with FAR 25.1002(c).

                  PART 426_OTHER SOCIOECONOMIC PROGRAMS

        Subpart 426.70_Preference for Selected Biobased Products

Sec.

Sec. 426.7000  Scope of subpart.

Sec. 426.7001  Applicability.

Sec. 426.7002  Authority.

Sec. 426.7003  Policy.

Sec. 426.7004  Definitions.

Sec. 426.7005  Preference list.

Sec. 426.7006  Use of a set-aside or a price preference.

Sec. 426.7007  Use of a technical evaluation preference.

Sec. 426.7008  Identification of preferred products.

Sec. 426.7009  Contract provisions.

    Authority: 5 U.S.C. 301; 7 U.S.C. 5909; 40 U.S.C. 486(c).

    Source: 63 FR 26997, May 15, 1998, unless otherwise noted.

        Subpart 426.70_Preference for Selected Biobased Products



Sec. 426.7000  Scope of subpart.

    This subpart supplements the FAR to implement the set-asides and 
preferences described in section 1665 of the Food, Agriculture, 
Conservation and Trade Act of 1990 (7 U.S.C. 5909).



Sec. 426.7001  Applicability.

    This subpart applies to USDA and all of its components, including 
corporations.



Sec. 426.7002  Authority.

    Section 1665 of the Food, Agriculture, Conservation and Trade Act of 
1990 (7 U.S.C. 5909) authorizes USDA to establish set-asides and other 
preferences for products that have been assisted by the Alternative 
Agricultural Research and Commercialization Corporation (AARCC).



Sec. 426.7003  Policy.

    (a) AARCC provides financial assistance to private companies and 
other parties to commercialize nonfood, nonfeed products made from 
agricultural and forestry materials and animal by-products (biobased 
products). Biobased products by their nature are environmentally 
friendly, and, in many instances, use agricultural material that 
otherwise would be waste. It is the policy of USDA to acquire AARCC 
products to the maximum extent practicable. This policy applies to all 
acquisitions of products regardless of dollar value.
    (b) USDA shall satisfy its requirements for products the same or 
essentially the same as AARCC products by applying the preferences or 
set-asides described by this subpart.



Sec. 426.7004  Definitions.

    As used in this subpart--
    AARCC products are products developed with assistance provided by 
AARCC as authorized by 7 U.S.C. 5905.
    Acquisitions of products means an acquisition of one or more 
products for the use of the Government.
    Acquisitions involving the use of products means an acquisition in 
which a Government contractor uses products in contract performance.
    Price preference means an amount, expressed as a percentage, to be 
used in the evaluation of offers in an acquisition of products.
    Set-aside means a requirement that vendors responding to a 
solicitation offer AARCC products.
    Solicitation includes actions taken under parts 12, 13, 14, 15, and 
36 of the Federal Acquisition Regulation.
    Technical evaluation preference means the use of an award factor or 
subfactor in which the Government expresses its preference for AARCC 
products.



Sec. 426.7005  Preference list.

    (a) The Office of Procurement and Policy Management (OPPM) and AARCC 
jointly shall establish and

[[Page 124]]

maintain a Preference List for AARCC products.
    (b) The Preference List shall contain the list of preferred 
products, source information for these products, the type(s) of 
preference to be applied, the beginning and ending dates for the use of 
preferences, and other terms established to define the preference given 
to a product.
    (c) The Preference List will be publicized within USDA by means of 
AGAR Advisories (see 401.371). Copies of the Preference List may be 
obtained from OPPM. The Preference List will also be posted on the World 
Wide Web at the USDA Procurement Home Page.



Sec. 426.7006  Use of a set-aside or a price preference.

    Acquisitions for products the same or essentially the same as those 
products appearing on the Preference List shall either be set-aside 
exclusively or shall include a price preference for those products shown 
on the Preference List. The actual price preference to be used shall be 
determined by the requiring office but may not exceed the percentage 
shown on the Preference List.



Sec. 426.7007  Use of a technical evaluation preference.

    Acquisitions involving the use of products the same or essentially 
the same as those products appearing on the Preference List shall 
include a technical evaluation preference, if authorized in the 
Preference List. The technical evaluation preference may be determined 
by the contracting officer specifically for each acquisition.



Sec. 426.7008  Identification of preferred products.

    (a) Products subject to a set-aside or technical preference shall be 
separately listed in the schedule, specification, or performance work 
statement.
    (b) Products subject to a price preference shall be separately 
listed in the schedule.



Sec. 426.7009  Contract provisions.

    (a) Each solicitation containing a price or technical preference 
under this subpart shall contain the provision 452.226-70, Preferred 
Products.
    (b) Each solicitation for products subject to a set-aside shall 
include the provision 452.226-71, Set-Aside For Mandatory Products.
    (c) Each solicitation for products subject to a price preference 
shall include the provision 452.226-72, Price Preference for Award.
    (d) Solicitations for products may contain both the provision in 
452.226-71 and the provision found in 452.226-72.
    (e) The provisions prescribed in this section are not required for 
acquisitions accomplished using the purchase card as a stand alone tool.

[[Page 125]]



              SUBCHAPTER E_GENERAL CONTRACTING REQUIREMENTS

                 PART 427_PATENTS, DATA, AND COPYRIGHTS

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

                          Subpart 427.1_General



Sec. 427.104  General guidance.

    As used in FAR part 27, the agency head or agency head designee is 
the Senior Procurement Executive, except under FAR 27.306(a) and (b). 
Under FAR 27.306(a) and (b), the agency head is the Secretary without 
power of redelegation.

[61 FR 53646, Oct. 15, 1996]

                      PART 428_BONDS AND INSURANCE

                           Subpart 428.1_Bonds

Sec.

Sec. 428.101   Bid guarantees.

Sec. 428.101-1   Policy on use.

Sec. 428.106   Administration.

Sec. 428.106-6  Furnishing information.

                         Subpart 428.2_Sureties


Sec. 428.203  Acceptability of individual sureties.

Sec. 428.204  Alternatives in lieu of corporate or individual sureties.

Sec. 428.204-2  Certified or cashier's checks, bank drafts, money 
          orders, or currency.

                         Subpart 428.3_Insurance


Sec. 428.307  Insurance under cost-reimbursement contracts.

Sec. 428.307-1  Group insurance plans.

Sec. 428.310  Contract clause for work on a Government installation.

Sec. 428.370  Government-owned vehicles operated in foreign countries.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                           Subpart 428.1_Bonds



Sec. 428.101  Bid guarantees.



Sec. 428.101-1  Policy on use.

    The Senior Procurement Executive may authorize class waivers of the 
requirement to obtain bid guarantees.



Sec. 428.106  Administration.



Sec. 428.106-6  Furnishing information.

    Heads of contracting activities (HCA's) or their designees may 
furnish certified copies of bonds and the contracts for which they were 
given as provided by FAR 28.106-6(c). Requesters may be required to pay 
costs of certification and copying established by the Departmental Fee 
Schedule for records requests (7 CFR part 1, subpart A, appendix A).

                         Subpart 428.2_Sureties



Sec. 428.203  Acceptability of individual sureties.

    Evidence of possible criminal or fraudulent activities by an 
individual surety shall be reported to the Office of Inspector General 
in accordance with Departmental Regulations (1700 series).



Sec. 428.204  Alternatives in lieu of corporate or individual sureties.

    HCA's shall establish procedures to ensure protection and conveyance 
of deposited securities of the types listed in FAR 28.204-1 through 
28.204-3.



Sec. 428.204-2  Certified or cashier's checks, bank drafts, money 
          orders, or currency.

    The contracting officer shall insert the provision at 452.228-70, 
Alternative Forms of Security, in a solicitation if a bond is required.

                         Subpart 428.3_Insurance



Sec. 428.307  Insurance under cost-reimbursement contracts.



Sec. 428.307-1  Group insurance plans.

    Under cost-reimbursement contracts, before buying insurance under a 
group

[[Page 126]]

insurance plan, the contractor shall submit the plan to the contracting 
officer for review. During review, the contracting officer shall use all 
sources of information available, such as audits, industry practice, or 
other sources of information, to determine whether acceptance of the 
plan submitted would be in the Government's best interest.



Sec. 428.310  Contract clause for work on a Government installation.

    The contracting officer shall insert the clause at 452.228-71, 
Insurance Coverage, in solicitations and contracts which include the 
clause at FAR 52.228-5, Insurance--Work on a Government Installation. If 
property liability insurance is required, the contracting officer shall 
use the clause with its Alternate I.



Sec. 428.370  Government-owned vehicles operated in foreign countries.

    USDA is authorized to obtain insurance to cover liability incurred 
by any of its employees while acting within the scope of their 
employment and operating a Government-owned vehicle in a foreign 
country. (7 U.S.C. 2262).

                           PART 429 [RESERVED]

            PART 430_COST ACCOUNTING STANDARDS ADMINISTRATION

Sec.

Sec. 430.070  Definitions.

                 Subpart 430.2_CAS Program Requirements


Sec. 430.201  Contract requirements.

Sec. 430.201-5  Waiver.

Sec. 430.202  Disclosure requirements.

Sec. 430.202-2  Impracticality of submission.

Sec. 430.202-8  Subcontractor Disclosure Statements.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.



Sec. 430.070  Definitions.

    ACO, as used in this part and in FAR part 30, means administrative 
contracting officer as described in FAR part 42.

                 Subpart 430.2_CAS Program Requirements



Sec. 430.201  Contract requirements.



Sec. 430.201-5  Waiver.

    The Senior Procurement Executive (SPE), without the authority to 
further redelegate, is authorized to request the Cost Accounting 
Standards Board to waive the application of the Cost Accounting 
Standards (CAS). Contracting officers shall prepare waiver requests in 
accordance with 48 CFR chapter 99 (Appendix B, FAR loose-leaf edition), 
subsection 9903.201-5, and submit them to the SPE through the head of 
the contracting activity (HCA).



Sec. 430.202  Disclosure requirements.



Sec. 430.202-2  Impracticality of submission.

    (a) The Secretary, without the power to delegate, is authorized to 
determine, in accordance with FAR part 99 (Appendix B), subsection 
9903.202-2, that the Disclosure Statement is impractical to secure and 
to authorize award without obtaining the Disclosure Statement.
    (b) The request for this determination is to be prepared in 
accordance with FAR part 99 (Appendix B), subsection 9903.202-2 and is 
to contain the proposed report to the CASB.
    (c) Requests for a determination under paragraph (a) of this section 
shall be prepared by the contracting officer and submitted through the 
HCA to the SPE for concurrence and submittal to the Secretary.



Sec. 430.202-8  Subcontractor Disclosure Statements.

    (a) The Secretary, without the power to redelegate, is authorized to 
determine that the Disclosure Statement for a subcontractor is 
impractical to secure and to authorize award without obtaining the 
Disclosure Statement.
    (b) Requests for this determination are to be prepared and forwarded 
as described in 430.202-2.

[[Page 127]]

            PART 431_CONTRACT COST PRINCIPLES AND PROCEDURES

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

                       Subpart 431.1_Applicability



Sec. 431.101  Objectives.

    (a) The SPE is designated as the official authorized to give advance 
approval of an individual deviation concerning cost principles.
    (b) The SPE is designated as the official authorized to give advance 
approval of a class deviation concerning cost principles after 
coordination with the Civilian Agency Acquisition Council.
    (c) Requests for advance approval of class deviations concerning 
cost principles must be submitted to the SPE through the HCA.

[61 FR 53646, Oct. 15, 1996]

                       PART 432_CONTRACT FINANCING

Sec.

Sec. 432.001  Definitions.

Sec. 432.003  Simplified acquisition procedures financing.

Sec. 432.006  Reduction or suspension of contract payments upon finding 
          of fraud.

Sec. 432.006-2  Definitions.

Sec. 432.006-3  Responsibilities.

Sec. 432.006-4  Procedures.

Sec. 432.006-5  Reporting.

          Subpart 432.1_Non-Commercial Item Purchase Financing


Sec. 432.102  Description of contract financing methods.

Sec. 432.103  Progress payments under construction contracts.

Sec. 432.111  Contract clauses for non-commercial purchases.

Sec. 432.113  Customary contract financing.

Sec. 432.114  Unusual contract financing.

            Subpart 432.2_Commercial Item Purchase Financing


Sec. 432.202  General.

Sec. 432.202-1  Policy.

Sec. 432.202-4  Security for Government financing.

Sec. 432.206  Solicitation provisions and contract clauses.

Sec. 432.207  Administration and payment of commercial financing 
          payments.

          Subpart 432.3_Loan Guarantees for Defense Production


Sec. 432.301  Definitions.

         Subpart 432.4_Advance Payments for Non-Commercial Items


Sec. 432.402  General.

Sec. 432.406  Letters of credit.

Sec. 432.407  Interest.

Sec. 432.412  Contract clause.

                      Subpart 432.6_Contract Debts


Sec. 432.601  Definition.

Sec. 432.616  Compromise actions.

                     Subpart 432.7_Contract Funding


Sec. 432.703  Contract funding requirements.

Sec. 432.703-3  Contracts crossing fiscal years.

Sec. 432.770  USDA specific funding limitations.

                   Subpart 432.8_Assignment of Claims


Sec. 432.802  Conditions.

Sec. 432.803  Policies.

Sec. 432.805  Procedure.

Sec. 432.806  Contract clauses.

                      Subpart 432.9_Prompt Payment


Sec. 432.905  Invoice payments.

Sec. 432.906  Contract financing payments.

                Subpart 432.10_Performance-Based Payments


Sec. 432.1007  Administration and payment of performance-based payments.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.



Sec. 432.001  Definitions.

    The agency contract finance office is the office, other than the 
office of the requisitioner, providing funding or performing funding 
record keeping for the contract action.
    Responsible fiscal authority is that officer in the agency contract 
finance office with the responsibility to ensure that adequate funds are 
available and usable for the intended purpose.



Sec. 432.003  Simplified acquisition procedures financing.

    (a) The chief of the contracting office may approve contract 
financing on a

[[Page 128]]

contract to be entered under the simplified acquisition procedures. 
Class approvals may not be made.
    (b) The signed approval must contain the supporting rationale for 
the action and an estimate of the cost and/or risk to the government.



Sec. 432.006  Reduction or suspension of contract payments upon finding 
          of fraud.



Sec. 432.006-2  Definitions.

    (a) The USDA remedy coordination official (RCO) is the Assistant 
Secretary for Administration.
    (b) For the purposes of this part, head of the agency means, 
exclusively, the Secretary or the Deputy Secretary.



Sec. 432.006-3  Responsibilities.

    When a contracting officer suspects that a request for advance, 
partial, or progress payment is based on fraud, the request shall be 
referred directly to the Office of Inspector General (OIG) in accordance 
with their instructions. A copy of the referral shall be submitted 
through the head of the contracting activity (HCA) to the Senior 
Procurement Executive (SPE).



Sec. 432.006-4  Procedures.

    (a) Immediately upon submittal of the referral described in 432.006-
3, the HCA and the contracting officer shall confer with the SPE and 
representatives of the OIG to discuss the potential for reduction or 
suspension of further payments based on the considerations listed in FAR 
32.006-4(d) (1) through (5).
    (b) The SPE will determine whether the contractor has contracts with 
other Departments or contracting activities and will involve them, as 
necessary, in the decision making process.
    (c) The OIG will determine the need for and the extent of an 
investigation.
    (d) Immediately upon completion of the OIG investigation (or, if 
deemed necessary by the OIG and the SPE, before completion of the 
investigation) the SPE, in coordination with the HCA, the contracting 
officer, and the OIG, shall make a report on the action to the RCO.
    (e) Upon receipt of the report, the RCO will submit a recommendation 
to the Secretary.
    (f) Upon receipt of the RCO's report the Secretary will:
    (1) Notify the contractor in writing, allowing 30 calendar days 
after receipt of the notice, that the contractor may submit in writing 
information and arguments in opposition to the recommendation; and
    (2) Consider the RCO's recommendation, the SPE's report, the 
response of the contractor, and any other relevant information in order 
to make an appropriate final determination.
    (g) This determination will be provided to the contractor and to the 
SPE for distribution to the agencies involved and for appropriate action 
under the determination.
    (h) The determination and the supporting documentation will be 
placed in the contract file(s) and a copy will be maintained by the SPE.
    (i) The contracting officer will advise the SPE of the actual date 
of the reduction or suspension action.
    (j) Not later than 150 calendar days after the actual date of the 
reduction or suspension action, the SPE will prepare for the RCO a 
review of the agency head's determination, and will propose a 
recommendation from the RCO to the agency head as to whether the 
reduction or suspension action should continue. The RCO will submit the 
recommendation (including a recommendation for the time period of a 
follow up review) to the agency head. This recommendation will be 
considered by the Secretary and handled as a final action described in 
paragraph (f) of this section.
    (k) The contract may not be closed nor final payment made prior to a 
final determination by the Secretary.



Sec. 432.006-5  Reporting.

    The annual report required by FAR 32.006-5 is to be prepared by the 
SPE and to be submitted to the Secretary within 90 calendar days after 
the end of the fiscal year. When signed by the Secretary, the report is 
to be maintained by the SPE.

[[Page 129]]

          Subpart 432.1_Non-Commercial Item Purchase Financing



Sec. 432.102  Description of contract financing methods.

    Progress payments based on a percentage or stage of completion are 
authorized for use as a payment method under USDA contracts or 
subcontracts for construction, alteration or repair, and shipbuilding 
and conversion. Such payments also are authorized for service contracts, 
if the contracting officer determines that progress payments based on 
costs are not practicable and adequate safeguards are provided to 
administer progress payments based on a percentage or stage of 
completion. For all other contracts, progress payment provisions shall 
be based on costs except that the HCA may authorize progress payments 
based on a percentage or stage of completion on a case-by-case basis. 
Each authorization by the HCA shall include a determination and finding 
that progress payments based on costs cannot be employed practically and 
that there are adequate safeguards provided for the administration of 
progress payments based on a percentage or stage of completion.



Sec. 432.103  Progress payments under construction contracts.

    (a) When approving a progress payment under a construction contract, 
the contracting officer shall indicate the amount to be paid by the 
payment office and include in the contract file the rationale in support 
of the payment.
    (b) When a retainage is made on a progress payment under a 
construction contract, the contracting officer shall place in the 
contract file a written determination stating the reason(s) for the 
retainage.
    (c) When a progress payment under a construction contract has been 
approved, the amount to be paid, the amount of any retainage withheld, 
and the reason(s) for the retainage shall be provided to the contractor 
by the contracting officer in writing before the payment due date.
    (d) When the contractor, under a fixed-price construction contract, 
furnishes evidence to the contracting officer that the surety has been 
paid in full for bond premiums and requests reimbursement, the first 
subsequent progress payment shall include the total amount attributable 
to such bond premiums and the Government shall pay that amount in full. 
This amount paid for the bond premiums is not an amount in addition to 
the stated contract price.



Sec. 432.111  Contract clauses for non-commercial purchases.

    The contracting officer shall insert the clause at 452.232-70, 
Reimbursement for Bond Premiums--Fixed Price Construction Contracts, 
whenever the clause at FAR 52.232-5, Payments under Fixed-Price 
Construction Contracts, is used in a contract.

[61 FR 53646, Oct. 15, 1996, as amended at 63 FR 26995, May 15, 1998]



Sec. 432.113  Customary contract financing.

    The contracting officer may determine the necessity for customary 
contract financing. The determination and finding that customary 
contract financing is needed shall be placed in the contract file.



Sec. 432.114   Unusual contract financing.

    The HCA is authorized to approve unusual contract financing. The 
signed determination and finding supporting this approval shall be 
included in the contract file.

            Subpart 432.2_Commercial Item Purchase Financing



Sec. 432.202   General.



Sec. 432.202-1   Policy.

    In the case of unusual contract financing, the approval by the HCA 
shall be recorded in a determination and finding and maintained in the 
contract file.



Sec. 432.202-4   Security for Government financing.

    Prior to determining that an offeror's financial condition is 
adequate security, the contracting officer must obtain the concurrence 
of the funding activity in the proposed determination.

[[Page 130]]



Sec. 432.206   Solicitation provisions and contract clauses.

    The responsibility for administration of the liquidation provisions 
of a contract may not be transferred from the contracting officer.



Sec. 432.207   Administration and payment of commercial financing 
          payments.

    The responsibility for receiving, reviewing, and approval of 
contract financing requests may not be transferred from the contracting 
officer.

          Subpart 432.3_Loan Guarantees for Defense Production



Sec. 432.301   Definitions.

    Within this subpart, the ``agency'' or ``guaranteeing agency'' is 
the ``head of the contracting activity'' (HCA) and may not be 
redelegated.

         Subpart 432.4_Advance Payments for Non-Commercial Items



Sec. 432.402   General.

    The HCA is designated as the individual responsible for making the 
findings and determination, and for approval of the contract terms 
concerning advance payments.



Sec. 432.406   Letters of credit.

    The HCA is designated as the individual responsible for coordination 
with the Department of Treasury concerning letters of credit.



Sec. 432.407   Interest.

    (a) The HCA is designated as the individual who may authorize, on a 
case by case basis, advance payments without interest for the contract 
types described in FAR 32.407(d)(1), (2), (3), and (4). The signed 
determination and findings supporting these authorizations shall be 
included in the contract files.
    (b) The SPE is designated as the individual who may authorize 
advance payments without interest other than those described in 
paragraph (a) of this section.



Sec. 432.412   Contract clause.

    The decision to use Alternates I or III to clause 52.232-12 must be 
supported by a determination and finding.

                      Subpart 432.6_Contract Debts



Sec. 432.601   Definition.

    Responsible official means the contracting officer.



Sec. 432.616   Compromise actions.

    Compromise of a debt within the proceedings under appeal to the 
Board of Contract Appeals is the responsibility of the contracting 
officer.

                     Subpart 432.7_Contract Funding



Sec. 432.703  Contract funding requirements.



Sec. 432.703-3  Contracts crossing fiscal years.

    Funds appropriated to USDA may be used for one-year contracts which 
are to be performed in two fiscal years so long as the total amount for 
such contracts is obligated in the year for which the funds are 
appropriated (7 U.S.C. 2209c).



Sec. 432.770   USDA specific funding limitations.

    (a) The USDA is authorized to subscribe for newspapers as may be 
necessary to carry out its authorized work: Provided, that such 
subscriptions shall not be made unless provision is made therefor in the 
applicable appropriation and the cost thereof is not in excess of 
limitations prescribed therein (7 U.S.C. 2258).
    (b) The expenditure of any USDA appropriation for any consulting 
service through any contract, pursuant to section 3109 of Title 5 of the 
U.S. Code shall be limited to those contracts where such expenditures 
are a matter of public record and available for public inspection, 
except where otherwise provided under existing law, or under existing 
Executive Order issued pursuant to existing law (7 U.S.C. 2225a).

[[Page 131]]

                   Subpart 432.8_Assignment of Claims



Sec. 432.802   Conditions.

    Written notices of assignment and a true copy of the assigned 
instrument are to be sent to the contracting officer rather than the 
agency head. Other copies are distributed as directed in FAR 32.802.



Sec. 432.803   Policies.

    The HCA may make a determination of need to include a no-setoff 
commitment in a contract.



Sec. 432.805   Procedure.

    The information described in FAR 32.805 shall be filed with the 
contracting officer.



Sec. 432.806   Contract clauses.

    The contracting officer may make the determination whether to 
include the clause at FAR 52.232-23 in any purchase order expected to 
exceed the micro-purchase threshold.

                      Subpart 432.9_Prompt Payment



Sec. 432.905   Invoice payments.

    The payment terms for supplies and services on the Procurement List 
and provided by a Javits-Wagner-O'Day Act participating nonprofit agency 
are governed by FAR 8.709.



Sec. 432.906   Contract financing payments.

    The HCA may prescribe, on a case-by-case basis, a shorter period for 
financing payments.

                Subpart 432.10_Performance-Based Payments



Sec. 432.1007   Administration and payment of performance-based 
          payments.

    The responsibility for receiving, reviewing, and approval of 
performance-based payment requests may not be transferred from the 
contracting officer.

                 PART 433_PROTESTS, DISPUTES AND APPEALS

                         Subpart 433.1_Protests

Sec.

Sec. 433.102  General.

Sec. 433.103  Protests to the agency.

Sec. 433.104  Protests to GAO.

                   Subpart 433.2_Disputes and Appeals


Sec. 433.203  Applicability.

Sec. 433.203-70  Agriculture Board of Contract Appeals.

Sec. 433.209  Suspected fraudulent claims.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                         Subpart 433.1_Protests



Sec. 433.102   General.

    (a) The Senior Procurement Executive (SPE) is responsible for 
coordinating the handling of bid protests lodged with the General 
Accounting Office (GAO).
    (b) The head of the contracting activity (HCA), on a non-delegable 
basis, may resolve protests and authorize reimbursement of costs in 
accordance with FAR 33.102(b).



Sec. 433.103   Protests to the agency.

    (a) Actual or prospective bidders or offerors may file protests 
either with the HCA, as provided by 433.102(b), or with the contracting 
officer. Protesters who file protests with the HCA shall furnish a 
complete copy to the contracting officer no later than 1 day after the 
protest is filed with the HCA.
    (b) When a protest is received, the adjudicating official shall take 
prompt action towards resolution and notify the protester in writing of 
the action taken. The written final decision shall include a paragraph 
substantially as follows:

    This decision shall be final and conclusive unless a further written 
notice of protest is filed with the General Accounting Office in 
accordance with 4 CFR part 21. Neither the filing of a protest with USDA 
nor the filing of a protest with the General Accounting Office affects 
your right to file an action

[[Page 132]]

in a district court of the United States or the United States Court of 
Federal Claims.



Sec. 433.104  Protests to GAO.

    The contracting activity shall furnish a copy of all reports 
submitted to the GAO, including all relevant documents, to the SPE 
simultaneously with their submission to the GAO.

                   Subpart 433.2_Disputes and Appeals



Sec. 433.203  Applicability.

    The Assistant Secretary for Administration is authorized to 
determine the applicability of the Contract Disputes Act to contracts 
with foreign governments pursuant to FAR 33.203.



Sec. 433.203-70  Agriculture Board of Contract Appeals.

    The organization, jurisdiction, and functions of the Agriculture 
Board of Contract Appeals, together with its Rules of Procedure, are set 
out in 7 CFR part 24.



Sec. 433.209  Suspected fraudulent claims.

    The contracting officer shall refer all matters related to suspected 
fraudulent claims by a contractor under the conditions in FAR 33.209 to 
the Office of Inspector General for additional action or investigation.

[[Page 133]]



             SUBCHAPTER F_SPECIAL CATEGORIES OF CONTRACTING

                    PART 434_MAJOR SYSTEM ACQUISITION

                          Subpart 434.0_General

Sec.

Sec. 434.001  Definitions.

Sec. 434.002  Policy.

Sec. 434.003  Responsibilities.

Sec. 434.004  Acquisition strategy.

Sec. 434.005  General requirements.

Sec. 434.005-6  Full production.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                          Subpart 434.0_General



Sec. 434.001  Definitions.

    Pursuant to OMB Circular No. A-109 (A-109) and the definition at FAR 
2.101, within USDA, a system shall be considered a major system if:
    (a) The total acquisition costs with private industry are estimated 
to be $50 million or more, or
    (b) The system has been specifically designated to be a major system 
by the USDA Acquisition Executive, even if the acquisition costs are not 
expected to exceed $50 million.

[61 FR 53646, Oct. 15, 1996, as amended at 63 FR 26995, May 15, 1998]



Sec. 434.002  Policy.

    In addition to the policy guidance at FAR 34.002, the policies 
outlined in paragraph 6 of A-109 should serve as guidelines for all 
contracting activities in planning and developing systems, major or 
otherwise.



Sec. 434.003  Responsibilities.

    (a) The Secretary of Agriculture or other designated USDA key 
executive is responsible for making four key decisions in each major 
system acquisition process. These are listed in paragraph 9 of A-109 and 
elaborated on in paragraphs 10 through 13. The key executives of USDA 
(Secretary, Deputy Secretary, Under Secretaries and Assistant 
Secretaries) individually or as a group will participate in this 
decision making process.
    (b) The Assistant Secretary for Administration (ASA) is the USDA 
Acquisition Executive. The ASA will ensure that A-109 is implemented in 
USDA and that the management objectives of the Circular are realized. 
The ASA is responsible for designating the program manager for each 
major system acquisition, designating an acquisition to be a major 
system acquisition, and approving the written charter and project 
control system for each major system acquisition.
    (c) The Procurement and Property Management staff is responsible for 
assisting the ASA in carrying out the above responsibilities.
    (d) Heads of contracting activities must:
    (1) Ensure compliance with the requirements of A-109, FAR part 34 
and AGAR 434.
    (2) Ensure that potential major system acquisitions are brought to 
the attention of the USDA Acquisition Executive.
    (3) Recommend qualified candidates for designation as program 
managers for each major system acquisition within their jurisdiction.
    (4) Ensure that program managers fulfill their responsibilities and 
discharge their duties.
    (5) Cooperate with the ASA in implementing the requirements of A-
109.
    (e) The program manager is responsible for planning and executing 
the major system acquisition, ensuring appropriate coordination with the 
USDA Acquisition Executive and other key USDA executives.



Sec. 434.004  Acquisition strategy.

    (a) The program manager will develop, in coordination with the 
Acquisition Executive, a written charter outlining the authority, 
responsibility, accountability, and budget for accomplishing the 
proposed objective.
    (b) The program manager will develop, subject to the approval of the 
Acquisition Executive, a project control system to schedule, monitor, 
and regularly report on all aspects of the

[[Page 134]]

project. The control system shall establish reporting periods and 
milestones consistent with the key decisions listed in paragraph 9 of A-
109.
    (c) Upon initiation of the project, the program manager will report 
regularly to the Acquisition Executive.



Sec. 434.005  General requirements.



Sec. 434.005-6  Full production.

    The Secretary or the USDA key executive designated by the Secretary 
for the specific program is the agency head for the purposes of FAR 
34.005-6.

              PART 435_RESEARCH AND DEVELOPMENT CONTRACTING

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).



Sec. 435.010  Scientific and technical reports.

    Research and development contracts shall contain a provision 
requiring that the contractor send copies of all scientific and 
technical reports to the National Technical Information Service at the 
address indicated in FAR 35.010(b). The release of research and 
development contract results to other government activities and to the 
private sector is subject to the provisions of FAR subpart 4.4.

[61 FR 53646, Oct. 15, 1996]

         PART 436_CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS

      Subpart 436.2_Special Aspects of Contracting for Construction

Sec.

Sec. 436.201  Evaluation of contractor performance.

Sec. 436.203  Government estimate of construction costs.

Sec. 436.204  Disclosure of the magnitude of construction projects.

Sec. 436.205  Statutory cost limitations.

Sec. 436.209  Construction contracts with architect-engineer firms.

Sec. 436.213  Special procedures for sealed bidding in construction 
          contracting.

Sec. 436.213-2  Presolicitation notices.

Subpart 436.3  [Reserved]

                     Subpart 436.5_Contract Clauses


Sec. 436.500  Scope of subpart.

Sec. 436.571  Prohibition against the use of lead-based paint.

Sec. 436.572  Use of premises.

Sec. 436.573  Archeological or historic sites.

Sec. 436.574  Control of erosion, sedimentation, and pollution.

Sec. 436.575  Maximum workweek-construction schedule.

Sec. 436.576  Samples and certificates.

Sec. 436.577  Emergency response.

Sec. 436.578  Standard specifications for construction of roads and 
          bridges.

Sec. 436.579  Opted timber sale road requirements.

                Subpart 436.6_Architect-Engineer Services


Sec. 436.601  Policy.

Sec. 436.601-3  Applicable contracting procedures.

Sec. 436.602  Selection of firms for architect-engineer contracts.

Sec. 436.602-1  Selection criteria.

Sec. 436.602-2  Evaluation boards.

Sec. 436.602-3  Evaluation board functions.

Sec. 436.602-4  Selection authority.

Sec. 436.602-5  Short selection process for contracts not to exceed the 
          simplified acquisition threshold.

Sec. 436.603  Collecting data on and appraising firms' qualifications.

Sec. 436.604  Performance evaluation.

Sec. 436.605  Government cost estimate for architect-engineer work.

Sec. 436.609  Contract clauses.

Sec. 436.609-1  Design within funding limitations.

Sec. 436.670  Firms ineligible for award--construction.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

      Subpart 436.2_Special Aspects of Contracting for Construction



Sec. 436.201  Evaluation of contractor performance.

    Preparation of performance evaluation reports. In addition to the 
requirements of FAR 36.201, performance evaluation reports shall be 
prepared for indefinite-delivery type contracts when either the contract 
maximum or the contracting activity's reasonable estimate of services to 
be ordered exceeds $500,000.00. For these contracts, performance 
evaluation reports shall be prepared for each order at the time of final 
acceptance of the work under the order.

[[Page 135]]



Sec. 436.203  Government estimate of construction costs.

    For acquisitions using sealed bid procedures, the contracting 
officer may disclose the overall amount of the Government's estimate of 
construction costs following identification of the responsive bid most 
advantageous to the Government; verification of that bid's price 
reasonableness; and verification of the bidder's responsibility. For 
acquisitions using other than sealed bid procedures (e.g., negotiation), 
the contracting officer may disclose the overall amount of the estimate 
after contract award.



Sec. 436.204  Disclosure of the magnitude of construction projects.

    In the case of indefinite-delivery type contracts, the reasonable 
estimate of work to be done or the maximum in the solicitation, both 
including all options, is to be used to select the price range. 
Contracting officers may elect to use both a price range for the base 
period of services and the total, inclusive of options, to best describe 
the magnitude of the solicitation.



Sec. 436.205  Statutory cost limitations.

    (a) When it appears that funds available for a project may be 
insufficient for all the desired features of construction, the 
contracting officer may provide in the solicitation for a base bid item 
covering the work generally as specified and for one or more additive or 
deductive bid items which progressively add or omit specified features 
of the work in a stated order of priority. In this case, the contracting 
officer shall insert the provision at 452.236-70, Additive or Deductive 
Items, in solicitations for construction.
    (b) In the alternative to the process in paragraph (a) of this 
section, the contracting officer may use the policies and procedures 
found in FAR 17.2.



Sec. 436.209  Construction contracts with architect-engineer firms.

    The head of the contracting activity (HCA) is authorized to approve 
the award of a contract to construct a project, in whole or in part, to 
the firm (inclusive of its subsidiaries or affiliates) that designed the 
project.



Sec. 436.213  Special procedures for sealed bidding in construction 
          contracting.



Sec. 436.213-2  Presolicitation notices.

    The authority to waive a presolicitation notice is restricted to the 
HCA.

[63 FR 26995, May 15, 1998]

Subpart 436.3  [Reserved]

                     Subpart 436.5_Contract Clauses



Sec. 436.500  Scope of subpart.

    This subpart prescribes clauses for insertion in USDA solicitations 
and contracts for construction and for dismantling, demolition, or 
removal of improvements or structures. The contracting officer shall use 
the clauses as prescribed, in contracts that exceed the simplified 
acquisition threshold. The contracting officer may use the clauses if 
the contract amount is expected to be within the simplified acquisition 
threshold.



Sec. 436.571  Prohibition against the use of lead-based paint.

    The contracting officer shall insert the clause at 452.236-71, 
Prohibition Against the Use of Lead-Based Paint, in solicitations and 
contracts, if the work involves construction or rehabilitation 
(including dismantling, demolition, or removal) of residential 
structures. This clause may be used in contracts for other than 
residential structures.



Sec. 436.572  Use of premises.

    The contracting officer shall insert the clause at 452.236-72, Use 
of Premises, if the contractor will be permitted to use land or premises 
administered by USDA.



Sec. 436.573  Archeological or historic sites.

    The contracting officer shall insert the clause at 452.236-73, 
Archeological or Historic Sites, if the contractor will be working in an 
area where such sites may be found. Use of the clause is optional in 
service contracts for on-the-ground work, e.g. reforestation, 
silvicultural, land stabilization, or other agricultural-related 
projects.

[[Page 136]]



Sec. 436.574  Control of erosion, sedimentation, and pollution.

    The contracting officer shall insert the clause at 452.236-74, 
Control of Erosion, Sedimentation and Pollution, if there is a need for 
applying environmental controls in the performance of work. Use of the 
clause is optional in service contracts for on-the-ground e.g., 
reforestation, silvicultural, land stabilization, or other agricultural-
related projects.



Sec. 436.575  Maximum workweek-construction schedule.

    The contracting officer shall insert the clause at 452.236-75, 
Maximum Workweek-Construction Schedule, if the clause at FAR 52.236-15 
is used and the contractor's work schedule is restricted by access to 
the facility or must be coordinated with the schedule of contract 
administration personnel.

[63 FR 26996, May 15, 1998]



Sec. 436.576  Samples and certificates.

    The contracting officer shall insert the clause at 452.236-76, 
Samples and Certificates, in all contracts.



Sec. 436.577  Emergency response.

    The contracting officer may insert the clause at 452.236-77, 
Emergency Response, in construction contracts awarded for the Forest 
Service.



Sec. 436.578  Standard specifications for construction of roads and 
          bridges.

    The contracting officer shall insert the clause at 452.236-78, 
Forest Service Standard Specifications for Construction of Roads and 
Bridges, in construction contracts that incorporate the standard 
specifications.



Sec. 436.579  Opted timber sale road requirements.

    The contracting officer shall insert the clause at 452.236-79, Opted 
Timber Sale Road Requirements, in road construction contracts resulting 
from a timber sale turnback.

                Subpart 436.6_Architect-Engineer Service



Sec. 436.601  Policy.



Sec. 436.601-3  Applicable contracting procedures.

    The technical official's listing of areas where recovered materials 
cannot be used shall be referred to the contracting activity's official 
designated in accordance with FAR 23.404. A copy of the listing and of 
any approval or disapproval by that official is to be retained in the 
solicitation file.



Sec. 436.602  Selection of firms for architect-engineer contracts.



Sec. 436.602-1  Selection criteria.

    The HCA is authorized to approve the use of design competition under 
the conditions in FAR 36.602-1(b).



Sec. 436.602-2  Evaluation boards.

    HCA's shall establish written procedures for providing permanent or 
ad hoc architect-engineer evaluation boards as prescribed in FAR 36.602-
2. The procedures may provide for the appointment of private 
practitioners of architecture, engineering, or related professions when 
such action is determined by the HCA to be essential to meet the 
Government's minimum needs.



Sec. 436.602-3  Evaluation board functions.

    The selection report required in FAR 36.602-3(d) shall be prepared 
for the approval of the HCA. The HCA may authorize an acquisition 
official above the level of the contracting officer to execute the 
required approval.



Sec. 436.602-4  Selection authority.

    (a) The HCA shall serve as the selection authority in accordance 
with FAR 36.602-4. The HCA may authorize an acquisition official above 
the level of the contracting officer to serve as the selection 
authority.
    (b) A copy of the final selection, inclusive of the supporting 
documents, shall be provided to the contracting officer and maintained 
in the solicitation file.

[[Page 137]]



Sec. 436.602-5  Short selection process for contracts not to exceed the 
          simplified acquisition threshold.

    The HCA may include either or both procedures in FAR 36.602-5 in the 
procedures for evaluation boards.



Sec. 436.603  Collecting data on and appraising firms' qualifications.

    (a) HCA's which require architect-engineer services shall establish 
procedures to comply with the requirements of FAR 36.603.
    (b) The procedures shall include a list of names, addresses, and 
phone numbers of offices or boards assigned to maintain architect-
engineer qualification data files. The list shall be updated annually.



Sec. 436.604  Performance evaluation.

    Preparation of performance evaluation reports. (a) In addition to 
the requirements of FAR 36.604, performance evaluation reports shall be 
prepared for indefinite-delivery type contracts when either the contract 
maximum or the contracting activities reasonable estimate of services to 
be ordered exceeds $25,000.00. For these contracts, performance 
evaluation reports shall be prepared for each order at the time of final 
acceptance of the work under the order.
    (b) The contracting officer may require a performance evaluation 
report on the work done by the architect-engineer after the completion 
of or during the construction of the designed project.



Sec. 436.605  Government cost estimate for architect-engineer work.

    The contracting officer may release the Government's total cost 
estimate in accordance with FAR 36.605(b).



Sec. 436.609  Contract clauses.



Sec. 436.609-1  Design within funding limitations.

    (a) Should the head of the contracting activity appoint a designee 
to make the determination in FAR 36.609-1(c)(1), the appointment may be 
to one no lower than the official authorized to commit program funds for 
the work being acquired.
    (b) The contracting officer, with the advice of appropriate 
technical representatives, may make the determination in FAR 36.609-
1(c)(2) or (3).
    (c) A copy of the determinations described in paragraph (b) and (c) 
of this section shall be maintained in the contract file.



Sec. 436.670  Firms ineligible for award--construction.

    The contracting officer shall insert the clause at 452.236-80, Firms 
Ineligible For Award--Construction, in the contract for architect-
engineering services except as provided in FAR 36.209 and AGAR 436.209.

                      PART 437_SERVICE CONTRACTING

                 Subpart 437.1_Service Contracts_General

Sec.

Sec. 437.104  Personal services contracts.

Sec. 437.110  Solicitation provisions and contract clauses.

             Subpart 437.2_Advisory and Assistance Services


Sec. 437.203  Policy.

Sec. 437.204  Guidelines for determining availability of personnel.

Sec. 437.270  Solicitation provisions and contract clauses.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                 Subpart 437.1_Service Contracts_General



Sec. 437.104  Personal services contracts.

    USDA has the following specific statutory authorities to contract 
for personal services:
    (a) Section 706(a) of the Organic Act of 1944 (7 U.S.C. 2225) 
authorizes contracting with persons or organizations on a temporary 
basis, without regard to civil service compensation classification 
standards in 5 U.S.C., Chapter 51 and Subchapter III of Chapter 53, 
Provided:
    (1) That no expenditures shall be made unless specifically provided 
for in the applicable appropriation, and

[[Page 138]]

    (2) Expenditures do not exceed any limitations prescribed in the 
appropriation.
    (b) 7 U.S.C. 1627 authorizes the Secretary of Agriculture to 
contract with technically qualified persons, firms or organizations to 
perform research, inspection, classification, technical, or other 
special services, without regard to the civil-service laws, Provided: it 
is for a temporary basis and for a term not to exceed six months in any 
fiscal year.



Sec. 437.110  Solicitation provisions and contract clauses.

    (a) The contracting officer shall insert a clause substantially the 
same as the clause at 452.237-70, Loss Damage, Destruction or Repair, in 
contracts for equipment rental, whether the equipment is furnished with 
or without operator.
    (b) The contracting officer shall insert a provision substantially 
the same as the clause at 452.237-71, Pre-Bid/Pre-Proposal Conference, 
in all solicitations if a conference with prospective offerors will be 
held prior to the submittal of bids or proposals.
    (c) The contracting officer shall insert the provision at 452.237-
73, Equipment Inspection visit, in solicitations if work is to be done 
on Government equipment and an offeror's inspection is encouraged for an 
understanding of the work to be performed prior to submittal of bids or 
proposals.
    (d) The contracting officer shall insert a clause substantially the 
same as the clause at 452.237-74, Key Personnel, in contracts if 
contract performance requires identification of the contractor's key 
personnel.
    (e) The contracting officer shall insert a clause substantially the 
same as the clause at 452.237-75, Restrictions Against Disclosure, in 
service contracts (including architect-engineer contracts) requiring 
restrictions on release of information developed or obtained in 
connection with performance of the contract.

             Subpart 437.2_Advisory and Assistance Services



Sec. 437.203  Policy.

    Contracting for advisory and assistance services is subject to the 
policy and procedures in Departmental Regulations (5000 series).



Sec. 437.204  Guidelines for determining availability of personnel.

    The head of the contracting activity (HCA) is authorized to approve 
the use of non-Government evaluators in proposal evaluation. Each such 
decision shall be supported by a written determination in accordance 
with FAR 37.204.

[64 FR 52675, Sept. 30, 1999]



Sec. 437.270  Solicitation and contract clauses.

    (a) The contracting officer shall insert a clause substantially the 
same as the clause at 452.237-76, Progress Reporting, in all contracts 
for advisory and assistance services. It may also be used in other 
service contracts.
    (b) The contracting officer shall insert a clause substantially the 
same as the clause at 452.237-78, Contracts with Consulting Firms for 
Services, in solicitations and contracts for consulting services which 
prohibit follow-on contracts with the contracting firm.

                        PARTS 438	440 [RESERVED]

                PART 441_ACQUISITION OF UTILITY SERVICES

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

                Subpart 441.2_Acquiring Utility Services



Sec. 441.201  Policy.

    As used in FAR 41.201(d)(2)(i) and 41.201(d)(3) the Federal agency 
head designee is the head of the contracting activity.

[61 FR 53646, Oct. 15, 1996]

[[Page 139]]



                    SUBCHAPTER G_CONTRACT MANAGEMENT

                    PART 442_CONTRACT ADMINISTRATION

  Subpart 442.1_Interagency Contract Administration and Audit Services

Sec.

Sec. 442.102  Procedures.

            Subpart 442.15_Contractor Performance Information


Sec. 442.1502  Policy.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

  Subpart 442.1_Interagency Contract Administration and Audit Services



Sec. 442.102  Procedures.

    (a) The Office of Inspector General (OIG), Audit Division, has 
established a cross-servicing arrangement with the Defense Contract 
Audit Agency (DCAA) to provide contract audit services required by the 
FAR.
    (b) All contract audit services required by contracting officers, 
except those which can be accomplished in-house, shall be coordinated 
through the cognizant OIG Regional Inspector General--Auditing (RIG-A). 
Cognizance is determined on the basis of the contractor's location. 
There is no charge for DCAA audit services coordinated through OIG.
    (c) In order to ensure compliance with this requirement and to 
evaluate the results of audits, contracting officers shall forward to 
the RIG-A copies of all price negotiation memoranda prepared for 
contracts and contract modifications in excess of $500,000.

            Subpart 442.15_Contractor Performance Information



Sec. 442.1502  Policy.

    The head of the contracting activity shall be responsible for 
establishing past performance evaluation procedures and systems as 
required by FAR 42.1502 and 42.1503.

    Effective Date Note: At 66 FR 49867, Oct. 1, 2001, Sec. 442.1502 was 
revised, effective Nov. 30, 2001. For the convenience of the user, the 
revised text is set forth as follows:

442.1502  Policy.

    The Contractor Performance System (CPS), developed by the National 
Institutes of Health, is designated as the single USDA-wide system for 
maintaining contractor performance/evaluation information. Use of the 
CPS is mandatory. As a minimum, the CPS shall be accessed for contractor 
past performance information as part of proposal evaluation in 
accordance with FAR subpart 15.3, and information resulting from the 
evaluation of contractor performance in accordance with FAR subpart 
42.15 shall be entered into and maintained in this system. The CPS is a 
part of the USDA Acquisition Toolkit which can be accessed from the USDA 
Procurement Homepage at http://www.usda.gov/procurement/.

                        PARTS 443	444 [RESERVED]

                      PART 445_GOVERNMENT PROPERTY

       Subpart 445.3_Providing Government Property to Contractors

Sec.

Sec. 445.302  Providing facilities.

Sec. 445.302-1  Policy.

     Subpart 445.4_Contractor Use and Rental of Government Property


Sec. 445.403  Rental--Use and Charges clause.

Sec. 445.407  Non-Government use of plant equipment.

   Subpart 445.6_Reporting, Redistribution and Disposal of Contractor 
                                Inventory


Sec. 445.608  Screening of contracting inventory.

Sec. 445.608-6  Waiver of screening requirements.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

[[Page 140]]

       Subpart 445.3_Providing Government Property to Contractors



Sec. 445.302  Providing facilities.



Sec. 445.302-1  Policy.

    Heads of contracting activities (HCA's) are authorized to make 
determinations for providing facilities to a contractor as prescribed in 
FAR 45.302-1(a)(4).

     Subpart 445.4_Contractor Use and Rental of Government Property



Sec. 445.403  Rental--Use and Charges clause.

    HCA's are authorized to make determinations for charging rent on the 
basis of use under the Use and Charges clause in FAR 52.245-9 as 
prescribed in FAR 45.403(a).



Sec. 445.407  Non-Government use of plant equipment.

    Requests for non-Government use of plant equipment as prescribed in 
FAR 45.407 shall be submitted by the HCA to the Senior Procurement 
Executive (SPE) for approval.

   Subpart 445.6_Reporting, Redistribution and Disposal of Contractor 
                                Inventory



Sec. 445.608  Screening of contractor inventory.



Sec. 445.608-6  Waiver of screening requirements.

    Requests to waive screening requirements as prescribed in FAR 
46.608-6 shall be submitted by the HCA to the SPE for approval.

                       PART 446_QUALITY ASSURANCE

    Authority: 5 U.S.C. 30 and 40 U.S.C. 486(c).

                     Subpart 446.3_Contract Clauses



Sec. 446.370  Inspection and acceptance.

    The Contracting Officer shall insert the clause at 452.246-70, 
Inspection and Acceptance, in contracts where inspection and acceptance 
will be performed at the same location. The clause with its Alternate I 
is for use when inspection and acceptance will be performed at different 
locations.

[61 FR 53646, Oct. 15, 1996]

                         PART 447_TRANSPORTATION

            Subpart 447.3_Transportation in Supply Contracts

Sec.

Sec. 447.302  Place of delivery--F.O.B. point.

Sec. 447.305  Solicitation provisions, contract clauses, and 
          transportation factors.

Sec. 447.305-10  Packing, marking, and consignment instructions.

    Authority: 5 U.S.C. 30 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

            Subpart 447.3_Transportation in Supply Contracts



Sec. 447.302  Place of delivery--F.O.B. point.

    The contracting officer shall insert a clause substantially the same 
as the clause at 452.247-70, Delivery Location, in supply contracts when 
it is necessary to specify delivery locations. If appropriate, the 
clause may reference an attachment which lists various delivery 
locations and other delivery details (e.g., quantities to be delivered 
to each location, etc.).



Sec. 447.305  Solicitation provisions, contract clauses, and 
          transportation factors.



Sec. 447.305-10  Packing, marking, and consignment instructions.

    (a) The contracting officer shall insert a clause substantially the 
same as the clause at 452.247-71, Marking Deliverables, in solicitations 
and contracts if special marking on deliverables (other than reports) 
are required.
    (b) The contracting officer shall insert the clause at 452.247-72, 
Packing for Domestic Shipment, in contracts when item(s) will be 
delivered for immediate use to a destination in the continental United 
States; when the

[[Page 141]]

material specification or purchase description does not provide 
preservation, packaging, packing, and/or marking requirements; and/or 
when the requiring activity has not cited a specific specification for 
packaging.
    (c) The contracting officer shall insert the clause at 452.247-73, 
Packing for Overseas Shipment, in contracts when item(s) will be 
delivered to an overseas destination for immediate use, the material 
specification does not specify packing levels, and the required activity 
has not specified such requirements.

                           PART 448 [RESERVED]

                    PART 449_TERMINATION OF CONTRACTS

                    Subpart 449.1_General Principles

Sec.

Sec. 449.106  Fraud or other criminal conduct.

Sec. 449.111  Review of proposed settlements.

                  Subpart 449.4_Termination for Default


Sec. 449.402  Termination of fixed-price contracts for default.

Sec. 449.402-3  Procedure for default.

               Subpart 449.5_Contract Termination Clauses


Sec. 449.501  General.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

                    Subpart 449.1_General Principles



Sec. 449.106  Fraud or other criminal conduct.

    (a) If the contracting officer suspects fraud or other criminal 
conduct a written report documenting the facts shall be submitted by the 
head of the contracting activity (HCA) to the Office of Inspector 
General. Copies of documents or other information connected with the 
suspected fraud or criminal conduct shall be provided with the report. 
Concurrently, a copy of the report shall also be submitted to the Senior 
Procurement Executive.
    (b) Depending on the findings of the Office of Inspector General, 
the HCA may initiate suspension or debarment action as prescribed in FAR 
part 9.4 and part 409.4.



Sec. 449.111  Review of proposed settlements.

    Proposed settlement agreements shall be reviewed and approved in 
accordance with contracting activity procedures.

                  Subpart 449.4_Termination for Default



Sec. 449.402  Termination of fixed-price contracts for default.



Sec. 449.402-3  Procedure for default.

    In addition to the requirements of FAR 49.402-3(g), the notice of 
termination shall contain instructions regarding the disposition of any 
Government property in the possession of the contractor (see FAR 45.508-
1) and, in the case of construction contracts, such materials, 
appliances, and structures as may be on the site of the construction 
work. The notice shall also contain a statement concerning the liability 
of the contractor or its surety for any liquidated damages (see FAR 
49.402-7).

               Subpart 449.5_Contract Termination Clauses



Sec. 449.501  General.

    Use of special purpose termination clauses pursuant to the authority 
of FAR 49.501 shall be approved in advance by the HCA.

               PART 450_EXTRAORDINARY CONTRACTUAL ACTIONS

Sec.

Sec. 450.001  Definitions.

                          Subpart 450.1_General


Sec. 450.104  Reports.

  Subpart 450.2_Delegation of and Limitations on Exercise of Authority


Sec. 450.201  Delegation of authority.

                   Subpart 450.3_Contract Adjustments


Sec. 450.303  Contract adjustment.

Sec. 450.303-1  Contractor requests.


[[Page 142]]


    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.



Sec. 450.001  Definitions.

    Approving authority, as used in this part, means the Assistant 
Secretary for Administration.
    Secretarial level, as used in this part means the Assistant 
Secretary for Administration.

                          Subpart 450.1_General



Sec. 450.104  Reports.

    The Senior Procurement Executive shall prepare the report required 
by FAR 50.104.

  Subpart 450.2_Delegation of and Limitations on Exercise of Authority



Sec. 450.201  Delegation of authority.

    The Assistant Secretary for Administration is authorized to approve 
all actions under FAR part 50 except indemnification actions listed in 
FAR 50.201(d) which must be approved by the Secretary, without power of 
delegation.

                   Subpart 450.3_Contract Adjustments



Sec. 450.303  Contract adjustment.



Sec. 450.303-1  Contractor requests.

    Contractor requests shall be submitted to the contracting officer.

                           PART 451 [RESERVED]

[[Page 143]]



                     SUBCHAPTER H_CLAUSES AND FORMS

          PART 452_SOLICITATION PROVISIONS AND CONTRACT CLAUSES

              Subpart 452.2_Texts of Provisions and Clauses

Sec.

Sec. 452.204-70  Inquiries.

Sec. 452.211-70  Brand Name or Equal.

Sec. 452.211-71  Equal Products Offered.

Sec. 452.211-72  Statement of Work/Specifications.

Sec. 452.211-73  Attachments to Statement of Work/Specifications.

Sec. 452.211-74  Period of Performance.

Sec. 452.211-75  Effective Period of the Contract.

Sec. 452.214-70  Award by Lot.

Sec. 452.215-71  Instructions for the Preparation of Technical and 
          Business Proposals.

Sec. 452.215-72  Amendments to Proposals.

Sec. 452.215-73  Post Award Conference.

Sec. 452.216-70  Award Fee.

Sec. 452.216-71  Base Fee and Award Fee Proposal.

Sec. 452.216-72  Evaluation Quantities--Indefinite-Delivery Contract.

Sec. 452.216-73  Minimum and Maximum Contract Amounts.

Sec. 452.216-74  Ceiling Price.

Sec. 452.216-75  Letter Contract.

Sec. 452.219-70  Size Standard and SIC Code Information.

Sec. 452.224-70  Confidentiality of Information.

Sec. 452.226-70  Preferred Products.

Sec. 452.226-71  Set-aside for Mandatory Products.

Sec. 452.226-72  Price Preference for Award.

Sec. 452.228-70  Alternative Forms of Security.

Sec. 452.228-71  Insurance Coverage.

Sec. 452.232-70  Reimbursement for Bond Premiums--Fixed-Price 
          Construction Contracts.

Sec. 452.236-70  Additive or Deductive Items.

Sec. 452.236-71  Prohibition Against the Use of Lead-Based Paint.

Sec. 452.236-72  Use of Premises.

Sec. 452.236-73  Archaeological or Historic Sites.

Sec. 452.236-74  Control of Erosion, Sedimentation, and Pollution.

Sec. 452.236-75  Maximum Workweek--Construction Schedule.

Sec. 452.236-76  Samples and Certificates.

Sec. 452.236-77  Emergency Response.

Sec. 452.236-78  Forest Service Standard Specifications for Construction 
          of Roads and Bridges.

Sec. 452.236-79  Opted Timber Sale Road Requirements.

Sec. 452.236-80  Firms Ineligible for Award--Construction.

Sec. 452.237-70  Loss, Damage, Destruction or Repair.

Sec. 452.237-71  Pre-Bid/Pre-Proposal Conference.

Sec. 452.237-73  Equipment Inspection Visit.

Sec. 452.237-74  Key Personnel.

Sec. 452.237-75  Restrictions Against Disclosure.

Sec. 452.237-76  Progress Reporting.

Sec. 452.237-78  Contracts with Consulting Firms for Services.

Sec. 452.246-70  Inspection and Acceptance.

Sec. 452.247-70  Delivery Location.

Sec. 452.247-71  Marking Deliverables.

Sec. 452.247-72  Packing for Domestic Shipment.

Sec. 452.247-73  Packing for Overseas Shipment.

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.

              Subpart 452.2_Texts of Provisions and Clauses



Sec. 452.204-70  Inquiries.

    As prescribed in 404.7001, insert the following provision:

                          Inquiries (FEB 1988)

    Inquiries and all correspondence concerning this solicitation should 
be submitted in writing to the Contracting Officer. Offerors should 
contact only the Contracting Officer issuing the solicitation about any 
aspect of this requirement prior to contract award.

                           (End of provision)



Sec. 452.211-70  Brand Name or Equal.

    As prescribed in 411.171, insert the following provision:

                     Brand Name or Equal (NOV 1996)

    (As used in this provision, the term ``brand name'' includes 
identification of products by make and model.)
    (a) If items called for by this solicitation have been identified by 
a ``brand name or equal'' description, such identification is intended 
to be descriptive, but not restrictive, and is to indicate the quality 
and characteristics of products that will be satisfactory. Offers of 
``equal'' products (including products of the brand name manufacturer 
other than the one described by brand name) will be considered for award 
if such products are clearly identified in the offer (see clause 
452.211-2) and are determined by the Contracting Officer to meet fully 
the salient characteristics requirements listed in the solicitation.

[[Page 144]]

    (b) Unless the offeror clearly indicates in its offer that it is 
offering an ``equal'' product, the offeror shall be considered as 
offering the brand name product(s) referenced in the solicitation.
    (c)(1) If the offeror proposes to furnish an ``equal'' product or 
products, the brand name(s), if any, and any other required information 
about the product(s) to be furnished shall be inserted in the space 
provided in the solicitation. The evaluation of offers and the 
determination as to the equality of the product(s) offered shall be the 
responsibility of the Government and will be based on information 
furnished by the offeror or identified in its offer as well as other 
information reasonably available to the contracting activity. Caution to 
offerors: The contracting activity is not responsible for locating or 
securing any information which is not identified in the offer and is not 
reasonably available to the contracting activity. Accordingly, to assure 
that sufficient information is available, the offeror must furnish as a 
part of its offer all descriptive material (such as cuts, illustrations, 
drawings, or other information) necessary for the contracting activity 
to (i) determine whether the product offered meets the salient 
characteristics requirement of the solicitation, and (ii) establish 
exactly what the offeror proposes to furnish and what the Government 
would be binding itself to purchase by making an award. The information 
furnished may include specific reference to information previously 
furnished or to information otherwise available to the contracting 
activity.
    (2) If an offeror proposes to modify a product so as to make it 
conform to the requirements of the solicitation, the offer shall include 
(i) a clear description of such proposed modifications and (ii) clearly 
marked descriptive material to show the proposed modifications.

                           (End of provision)

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26996, May 15, 1998.]



Sec. 452.211-71  Equal Products Offered.

    As prescribed in 411.171, insert the following or substantially the 
same clause in solicitations seeking offers on a ``brand name or equal'' 
basis to allow offerors the opportunity to clearly identify the 
``equal'' item being offered, and to illustrate how that item meets the 
salient characteristics requirements of the Government.

                    Equal Products Offered (NOV 1996)

    (a) Offerors proposing to furnish an ``equal'' product, in 
accordance with the ``Brand Name or Equal'' provision of this 
solicitation, shall provide the following information for each offered 
``equal'' product:
Contract Line Item Number (if any):_____________________________________
Brand Name or Equal Product identified by the Government in this 
solicitation:___________________________________________________________
Offered Product Name:___________________________________________________
Catalog Description or part number:_____________________________________
_______________________________________________________________________
Manufacturer's Name:____________________________________________________
Manufacturer's Address:_________________________________________________
_______________________________________________________________________
_______________________________________________________________________
    (b) Offerors are responsible for submitting all additional 
information on the above product necessary for the Contracting Officer 
to determine whether the product offered meets the ``brand name or 
equal'' product's salient characteristics listed in the solicitation.

                             (End of clause)

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26996, May 15, 1998.]



Sec. 452.211-72  Statement of Work/Specifications.

    As prescribed in 411.171, insert the following clause:

               Statement of Work/Specifications (FEB 1988)

    The Contractor shall furnish the necessary personnel, material, 
equipment, services and facilities (except as otherwise specified), to 
perform the Statement of Work/Specifications referenced in Section J.

                             (End of clause)

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26996, May 15, 1998.]



Sec. 452.211-73  Attachments to Statement of Work/Specifications.

    As prescribed in 411.171, insert the following clause:

       Attachments to Statement of Work/Specifications (FEB 1988)

    The attachments to the Statement of Work/Specifications listed in 
Section J are hereby made part of this solicitation and any resultant 
contract.

                             (End of clause)

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26996, May 15, 1998.]



Sec. 452.211-74  Period of Performance.

    As prescribed in 411.404(a), insert the following clause:

[[Page 145]]

                    Period of Performance (FEB 1988)

    The period of performance of this contract is from ___ through ___.*

                             (End of clause)

    * Contracting Officer shall insert the appropriate dates.

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26996, May 15, 1998.]



Sec. 452.211-75  Effective Period of the Contract.

    As prescribed in 411.404(b), insert the following clause:

               Effective Period of the Contract (FEB 1988)

    The effective period of this contract is from ___ through ___.*

                             (End of clause)

    * Contracting Officer shall insert the appropriate dates.

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26996, May 15, 1998.]



Sec. 452.214-70  Award by Lot.

    As prescribed in 414.201-6, insert a provision substantially as 
follows:

                         Award by Lot (NOV 1996)

    Subject to the Section L provision FAR 52.214-10, ``Contract Award--
Sealed Bidding,'' award will generally be made to a single bidder on 
each entire lot. However, the Government reserves the right to award by 
item within any lot when the contracting officer determines that it is 
advantageous to the Government.

                           (End of provision)



Sec. 452.215-71  Instructions for the Preparation of Technical and 
          Business Proposals.

    As prescribed in 415.209(a), insert a provision substantially as 
follows:

Instructions for the Preparation of Technical and Business Proposals(SEP 
                                  1999)

    (a) General Instructions. Proposals submitted in response to this 
solicitation shall be furnished in the following format with the numbers 
of copies as specified below.
    (1) The proposal must include a technical proposal and business 
proposal. Each of the parts shall be separate and complete so that 
evaluation of one may be accomplished independently from evaluation of 
the other. The technical proposal must not contain reference to cost; 
however, resource information (such as data concerning labor hours and 
categories, materials, subcontracts, etc.) must be contained in the 
technical proposal so that the contractor's understanding of the 
statement of work may be evaluated.
    (2) Offerors may, at their discretion, submit alternate proposals or 
proposals which deviate from the requirement; provided, that an offeror 
also submit a proposal for performance of the work as specified in the 
statement of work. Any ``alternate'' proposal may be considered if 
overall performance would be improved or not compromised, and if it is 
in the best interest of the Government. Alternate proposals, or 
deviations from any requirement of this RFP, must be clearly identified.
    (3) The Government will evaluate proposals in accordance with the 
evaluation criteria set forth in Section M of this RFP.
    (4) Offerors shall submit their proposal(s) in the following format 
and the quantities specified:
    (a) ___* copies of the completed, signed offer (Sections A through K 
of the solicitation package)
    (b) ___* copies of the technical proposal
    (c) ___* copies of the business/cost proposal
    (b) Technical Proposal Instructions. The technical proposal will be 
used to make an evaluation and arrive at a determination as to whether 
the proposal will meet the requirements of the Government. Therefore, 
the technical proposal must present sufficient information to reflect a 
thorough understanding of the requirements and a detailed, description 
of the techniques, procedures and program for achieving the objectives 
of the specifications/statement of work. Proposals which merely 
paraphrase the requirements of the Government's specifications/ 
statement of work, or use such phrases as ``will comply'' or ``standard 
techniques will be employed'' will be considered unacceptable and will 
not be considered further. As a minimum, the proposal must clearly 
provide the following:
    (Contracting Officer shall identify in this section the minimum 
information required to evaluate each technical evaluation factor listed 
in Section M.)
    (c) Business Proposal Instructions.
    (1) Cost Proposal.
    In addition to any other requirements for cost/pricing information 
required in clause FAR 52.215-20, Requirements for Cost or Pricing Data 
or Information Other Than Cost or Pricing Data (OCT 1997), the following 
is required:
    (Contracting Officer shall identify additional information required 
if appropriate.)
    (2) Business Proposal.
    (a) Furnish financial statements for the last two years, including 
an interim statement for the current year, unless previously provided to 
the office issuing the RFP, in

[[Page 146]]

which case a statement as to when and where this information was 
provided may be furnished instead.
    (b) Specify the financial capacity, working capital and other 
resources available to perform the contract without assistance from any 
outside source.
    (c) Provide the name, location, and intercompany pricing policy for 
other divisions, subsidiaries, parent company, or affiliated companies 
that will perform work or furnish materials under this contract.

                           (End of provision)

    *Contracting officer shall insert number of copies required.

[61 FR 53646, Oct. 15, 1996, as amended at 64 FR 52675, Sept. 30, 1999]



Sec. 452.215-72  Amendments to Proposals.

    As prescribed in 415.209(b), insert the following provision:

                   Amendments to Proposals (FEB 1988)

    Any changes to a proposal made by the offeror after its initial 
submittal shall be accomplished by replacement pages. Changes from the 
original page shall be indicated on the outside margin by vertical lines 
adjacent to the change. The offeror shall include the date of the 
amendment on the lower right corner of the changed pages.

                           (End of provision)

[61 FR 53646, Oct. 15, 1996, as amended at 64 FR 52675, Sept. 30, 1999]



Sec. 452.215-73  Post Award Conference.

    As prescribed in 415.570, insert a clause substantially as follows:

                    Post Award Conference (NOV 1996)

    A post award conference with the successful offeror is required. It 
will be scheduled within ___* days after the date of contract award. The 
conference will be held at: ___*.

                             (End of clause)

    * Contracting officer to insert number of days and location.

[61 FR 53646, Oct. 15, 1996, as amended at 64 FR 52675, Sept. 30, 1999]



Sec. 452.216-70  Award Fee.

    As prescribed in 416.405, insert a clause substantially as follows:

                          Award Fee (FEB 1988)

    The amount of award fee the Contractor earns, if any, is based on a 
subjective evaluation by the Government of the quality of the 
Contractor's performance in accordance with the award fee plan. The 
Government will determine the amount of award fee every ___* months 
beginning with ___*. The Fee Determination Official (FDO) will 
unilaterally determine the amount of award fee. The FDO's determination 
will be in writing to the Contractor and is not subject to the 
``Disputes'' clause. The Government may unilaterally change the award 
fee plan at any time and will provide such changes in writing to the 
Contractor prior to the beginning of the applicable evaluation period. 
The Contractor may submit a voucher for the earned award fee. Available 
award fee not earned during one period does not carry over to subsequent 
periods.

                             (End of clause)

    * Contracting Officer shall insert appropriate number of months.
    ** Contracting Officer shall insert appropriate date.



Sec. 452.216-71  Base Fee and Award Fee Proposal.

    As prescribed in 416.470, insert the following provision:

                 Base Fee and Award Proposal (FEB 1988)

    For the purpose of this solicitation, offerors shall propose a base 
fee of ___* percent of the total estimated cost proposed. The award fee 
shall not exceed ___* percent of the total estimated cost.

                           (End of provision)

    * Contracting Officer shall insert appropriate percentages.



Sec. 452.216-72  Evaluation Quantities--Indefinite-Delivery Contract.

    As prescribed in 416.506(a), insert a provision substantially as 
follows:

     Evaluation Quantities--Indefinite-Delivery Contract (FEB 1988)

    To evaluate offers for award purposes, the Government will apply the 
offeror's proposed fixed-prices/rates to the estimated quantities 
included in the solicitation, and will add other direct costs if 
applicable.

[[Page 147]]

                           (End of provision)



Sec. 452.216-73  Minimum and Maximum Contract Amounts.

    As prescribed in 416.506(b), insert the following clause:

             Minimum and Maximum Contract Amounts (FEB 1988)

    During the period specified in FAR clause 52.216-18, ORDERING, the 
Government shall place orders totaling a minimum of ___*, but not in 
excess of ___*.

                             (End of clause)

    * Contracting Officer shall insert appropriate quantity or dollar 
amounts.



Sec. 452.216-74  Ceiling Price.

    As prescribed in 416.670, insert the following clause:

                        Ceiling Price (FEB 1988)

    The ceiling price of this contract is $___*. The Contractor shall 
not make expenditures or incur obligations in the performance of this 
contract which exceed the ceiling price specified herein, except at the 
Contractor's own risk.

                             (End of clause)

    *Contracting Officer shall insert appropriate dollar amount.



Sec. 452.216-75  Letter Contract.

    As prescribed in 416.603-4, insert the following clause:

                       Letter Contract (FEB 1988)

    This contract replaces letter contract No. ___* dated ___* and all 
amendments thereto.

                             (End of clause)

    * Contracting Officer shall insert number and date.



Sec. 452.219-70  Size Standard and SIC Code Information.

    As prescribed in 419.508, insert the following provision:

            Size Standard and SIC Code Information (NOV 1996)

    The Standard Industrial Classification Code(s) and business size 
standard(s) describing the products and/or services to be acquired under 
this solicitation are listed below:

Contract line item(s): ___* SIC Code ___* Size Standard ___*

                           (End of provision)

    * Contracting Officer shall insert the appropriate data for each 
contract line item in the solicitation. The data entry line may be 
duplicated as required to describe all of the contract line items or 
sub-items.

    Effective Date Note: At 66 FR 49317, Sept. 27, 2001, Sec. 452.219-70 
was amended by removing the acronym ``SIC'' and adding, in its place, 
the acronym ``NAICS''; removing the date ``NOV 1996'' and adding, in its 
place, the date ``SEP 2001''; and removing the words ``Standard 
Industrial Classification'' and adding, in their place, the words 
``North American Industrial Classification System'', effective Nov. 26, 
2001.



Sec. 452.224-70  Confidentiality of Information.

    As prescribed in 424.104, insert a clause substantially as follows:

                Confidentiality of Information (FEB 1988)

    (a) Confidential information, as used in this clause, means--
    (1) information or data of a personal nature, proprietary about an 
individual, or (2) information or data submitted by or pertaining to an 
organization.
    (b) In addition to the types of confidential information described 
in (a)(1) and (2) above, information which might require special 
consideration with regard to the timing of its disclosure may derive 
from studies or research, during which public disclosure of primarily 
invalidated findings could create an erroneous conclusion which might 
threaten public health or safety if acted upon.
    (c) The Contracting Officer and the Contractor may, by mutual 
consent, identify elsewhere in this contract specific information and/or 
categories of information which the Government will furnish to the 
Contractor or that the Contractor is expected to generate which is 
confidential. Similarly, the Contracting Officer and the Contractor may, 
by mutual consent, identify such confidential information from time to 
time during the performance of the contract. Failure to agree will be 
settled pursuant to the ``Disputes'' clause.
    (d) If it is established that information to be utilized under this 
contract is subject to the Privacy Act, the Contractor will follow the 
rules and procedures of disclosure set forth in the Privacy Act of 1974, 
5 U.S.C. 552a, and implementing regulations and policies, with respect 
to systems of records determined to be subject to the Privacy Act.
    (e) Confidential information, as defined in (a)(1) and (2) above, 
shall not be disclosed

[[Page 148]]

without the prior written consent of the individual, institution or 
organization.
    (f) Written advance notice of at least 45 days will be provided to 
the Contracting Officer of the Contractor's intent to release findings 
of studies or research, which have the possibility of adverse effects on 
the public or the Federal agency, as described in (b) above. If the 
Contracting Officer does not pose any objections in writing within the 
45 day period, the Contractor may proceed with disclosure. Disagreements 
not resolved by the Contractor and Contracting Officer will be settled 
pursuant to the ``Disputes'' clause.
    (g) Whenever the Contractor is uncertain with regard to the proper 
handling of material under the contract, or if the material in question 
is subject to the Privacy Act or is confidential information subject to 
the provisions of this clause, the Contractor shall obtain a written 
determination from the Contracting Officer prior to any release, 
disclosure, dissemination, or publication.
    (h) The provisions of paragraph (e) of this clause shall not apply 
when the information is subject to conflicting or overlapping provisions 
in other Federal, State or local laws.

                             (End of clause)



Sec. 452.226-70  Preferred Products.

    As prescribed in 426.7009(a), include the following provision:

                      Preferred Products (MAY 1998)

    Specific products required by this solicitation and resulting 
contract are subject to a price or a technical preference. A list of 
these products, the specific preference, and the manufacturer or 
producer is included below.

Contract Line Item (or other location in this solicitation): *__________

Product:________________________________________________________________

Manufacturer/Producer: *________________________________________________
_______________________________________________________________________
_______________________________________________________________________
_______________________________________________________________________

Preference: *___________________________________________________________
_______________________________________________________________________

                           (End of provision)

    * For each line item to which a preference applies, Contracting 
Officer shall insert appropriate information.

[63 FR 26998, May 15, 1998]



Sec. 452.226-71  Set-aside for Mandatory Products.

    As prescribed in 426.7009(b), include the following provision:

               Set-Aside for Mandatory Products (MAY 1998)

    Specific products are set-aside as mandatory products. These are 
separately listed in the schedule, specifications, or performance work 
statement. Specific terms governing the set-aside, and source 
information for the products are shown below.

Contract Line Item (or other location in this solicitation): *__________
_______________________________________________________________________

Product: *______________________________________________________________

Manufacturer/Producer: *________________________________________________
_______________________________________________________________________
_______________________________________________________________________
_______________________________________________________________________

Set-Aside Terms: *______________________________________________________
_______________________________________________________________________

                           (End of provision)

    * For each line item to which a set-aside applies, Contracting 
Officer shall insert appropriate information.

[63 FR 26998, May 15, 1998]



Sec. 452.226-72  Price Preference for Award.

    As prescribed in 426.7009(c), include the following provision:

                  Price Preference for Award (MAY 1998)

    Certain products listed in the schedule of this solicitation are 
subject to a price preference. A list of these products, the amount of 
the preference, and source information is included in provision 452.226-
70, Preferred Products. For purposes of evaluation of offers only, the 
offered prices for these products will be reduced by the price 
preference listed in the solicitation.

                           (End of provision)

[63 FR 26998, May 15, 1998]



Sec. 452.228-70  Alternative Forms of Security.

    As prescribed in 428.204-2, insert the following provision:

                Alternative Forms of Security (NOV 1996)

    If furnished as security, money orders, drafts, cashiers checks, or 
certified checks shall be drawn payable to: ___*.

                           (End of provision)

    * Contracting Officer shall insert the name of the USDA contracting 
activity.

[[Page 149]]



Sec. 452.228-71  Insurance Coverage.

    As prescribed in 428.310, insert the following clause:

                      Insurance Coverage (NOV 1996)

    Pursuant to FAR clause 52.228-5, Insurance-Work on a Government 
Installation, the Contractor will be required to present evidence to 
show, as a minimum, the amounts of insurance coverage indicated below:
    (a) Workers Compensation and Employer's Liability. The Contractor is 
required to comply with applicable Federal and State workers' 
compensation and occupational disease statutes. If occupational diseases 
are not compensable under those statutes, they shall be covered under 
the employer's liability section of the insurance policy, except when 
contract operations are so commingled with a Contractor's commercial 
operations that it would not be practical to require this coverage. 
Employer's liability coverage of at least $100,000 shall be required, 
except in States with exclusive or monopolistic funds that do not permit 
worker's compensation to be written by private carriers.
    (b) General Liability. The Contractor shall have bodily injury 
liability insurance coverage written on a comprehensive form of policy 
of at least $500,000 per occurrence.
    (c) Automobile Liability. The Contractor shall have automobile 
liability insurance written on a comprehensive form of policy. The 
policy shall provide for bodily injury and property damage liability 
covering the operation of all automobiles used in connection with 
performing the contract. Policies covering automobiles operated in the 
United States shall provide coverage of at least $200,000 per person and 
$500,000 per occurrence for bodily injury and $20,000 per occurrence for 
property damage or loss.
    (d) Aircraft Public and Passenger Liability. When aircraft are used 
in connection with performing the contract, the Contractor shall have 
aircraft public and passenger liability insurance. Coverage shall be at 
least $200,000 per person and $500,000 per occurrence for bodily injury, 
other than passenger injury. Coverage for passenger injury shall be at 
least $200,000 multiplied by the number of seats or passengers, 
whichever is greater.

                             (End of clause)

    Alternate I (NOV 1996). As prescribed in 428.310, substitute the 
following paragraph (b), when additionally the contractor must have 
property damage liability coverage:

    (b) General Liability. (1) The Contractor shall have bodily injury 
liability coverage written on a comprehensive form of policy of at least 
$500,000 per occurrence.
    (2) The Contractor shall have property damage liability insurance 
shall be required in the amount of ___* per occurrence.
    * Contracting Officer shall insert amount required.



Sec. 452.232-70  Reimbursement for Bond Premiums--Fixed-Price 
          Construction Contracts.

    As prescribed in 432.111, insert the following clause:

Reimbursement for Bond Premiums--Fixed-Price Construction Contracts (NOV 
                                  1996)

    The Contract Price includes the total amount for premiums that the 
Contractor attributes to the furnishing of performance and payment bonds 
required by the contract. Reimbursement for bond premiums under the 
clause at FAR 52.232-5, Payments Under Fixed-Price Construction 
Contract, shall not cover any amount therefor not included in the 
contract price.

                             (End of clause)

[61 FR 53646, Oct. 15, 1996. Redesignated at 63 FR 26996, May 15, 1998.]



Sec. 452.236-70  Additive or Deductive Items.

    As prescribed in 436.205, insert the following provision:

                 Additive or Deductive Items (FEB 1988)

    The low bidder for purposes of award shall be the conforming 
responsible bidder offering the low aggregate amount for the first or 
base bid item, plus or minus (in the order of priority listed in the 
schedule) those additive or deductive bid items providing the most 
features of the work within the funds determined by the government to be 
available before bids are opened. If addition of another bid item in the 
listed order of priority would make the award exceed such funds for all 
bidders, it shall be skipped and the next subsequent additive bid item 
in a lower amount shall be added if award therein can be made within 
such funds. For example, when the amount available is $100,000 and a 
bidder's base bid and four successive additives are $85,000, $10,000, 
$8,000, $6,000, and $4,000, the aggregate amount of the bid for purposes 
of award would be $99,000 for the base bid plus the first and fourth 
additives, the second and third additives being skipped because of each 
of them would cause the aggregate bid to exceed $100,000. In any case 
all bids shall be evaluated on the basis of the same additive or 
deductive bid items, determined as above provided. The listed order of

[[Page 150]]

priority need be followed only for determining the low bidder. After 
determination of the low bidder as stated, award in the best interests 
of the Government may be made on the selected first or base bid item and 
any combination of additive or deductive items for which funds are 
determined to be available at the time of the award, provided that award 
on such combination of bid items does not exceed the amount offered by 
any other conforming responsible bidder for the same combination of bid 
items.

                             (End of clause)



Sec. 452.236-71  Prohibition Against the Use of Lead-Based Paint.

    As prescribed in 436.571, insert the following clause:

       Prohibition Against the Use of Lead-Based Paint (NOV 1996)

    Neither the Contractor nor any subcontractor performing under this 
contract shall use paints containing more then 0.06 of 1 percent lead by 
weight (calculated as lead metal) in the total nonvolatile content of 
the paint, or the equivalent measure of lead in the dried film of paint 
already applied, or both.

                             (End of clause)



Sec. 452.236-72  Use of Premises.

    As prescribed in 436.572, insert the following clause:

                       Use of Premises (NOV 1996)

    (a) Before any camp, quarry, borrow pit, storage, detour, or bypass 
site, other than shown on the drawings, is opened or operated on USDA 
land or lands administered by the USDA, the Contractor shall obtain 
written permission from the Contracting Officer. A camp is interpreted 
to include a campsite or trailer parking area of any employee working on 
the project for the Contractor.
    (b) Unless excepted elsewhere in the contract, the Contractor shall 
(i) provide and maintain sanitation facilities for the work force at the 
site and (ii) dispose of solid waste in accordance with applicable 
Federal, State and local regulations.

                             (End of clause)



Sec. 452.236-73  Archaeological or Historic Sites.

    As prescribed in 436.573, insert the following clause:

               Archaeological or Historic Sites (FEB 1988)

    If a previously unidentified archaeological or historic site(s) is 
encountered, the Contractor shall discontinue work in the general area 
of the site(s) and notify the Contracting Officer immediately.

                             (End of clause)



Sec. 452.236-74  Control of Erosion, Sedimentation, and Pollution.

    As prescribed in 436.574, insert the following clause:

       Control of Erosion, Sedimentation, and Pollution (NOV 1996)

    (a) Operations shall be scheduled and conducted to minimize erosion 
of soils and to prevent silting and muddying of streams, rivers, 
irrigation systems, and impoundments (lakes, reservoirs, etc.).
    (b) Pollutants such as fuels, lubricants, bitumens, raw sewage, and 
other harmful materials shall not be discharged on the ground; into or 
nearby rivers, streams, or impoundments; or into natural or man-made 
channels. Wash water or waste from concrete or aggregate operations 
shall not be allowed to enter live streams prior to treatment by 
filtration, settling, or other means sufficient to reduce the sediment 
content to not more than that of the stream into which it is discharged.
    (c) Mechanized equipment shall not be operated in flowing streams 
without written approval by the Contracting Officer.

                             (End of clause)



Sec. 452.236-75  Maximum Workweek--Construction Schedule.

    As prescribed in 436.575, insert the following clause:

           Maximum Workweek--Construction Schedule (NOV 1996)

    Within __ calendar days after receipt of a written request from the 
Contracting Officer, the Contractor must submit the following in writing 
for approval:
    (a) A schedule as required by FAR clause 52.236-15, Schedules for 
Construction Contracts, and
    (b) The hours (including the daily starting and stopping times) and 
days of the week the Contractor proposes to carry out the work.
    The maximum workweek that will be approved is __*.

                             (End of clause)

    * Contracting Officer shall insert appropriate number of days and 
hours and/or days.

[[Page 151]]



Sec. 452.236-76  Samples and Certificates.

    As prescribed in 436.576, insert the following clause:

                   Samples and Certificates (FEB 1988)

    When required by the specifications or the Contracting Officer, 
samples, certificates, and test data shall be submitted after award of 
the contract, prepaid, in time for proper action by the Contracting 
Officer or his/her designated representative. Certificates and test data 
shall be submitted in triplicate to show compliance with materials and 
construction specified in the contract performance requirements.
    Samples shall be submitted in duplicate by the Contractor, except as 
otherwise specified, to show compliance with the contract requirements. 
Materials or equipment for which samples, certifications or test data 
are required shall not be used in the work until approved in writing by 
the Contracting Officer.

                             (End of clause)



Sec. 452.236-77  Emergency Response.

    As prescribed in 436.577, the following clause may be used in Forest 
Service construction contracts:

                      Emergency Response (NOV 1996)

    (a) Contractor's Responsibility for Fire Fighting. (1) The 
Contractor, under the provisions of FAR clause 52.236-9, Protection of 
Existing Vegetation, Structures, Equipment, Utilities, and Improvements, 
shall immediately extinguish all fires on the work site other than those 
fires in use as a part of the work.
    (2) The Contractor may be held liable for all damages and for all 
costs incurred by the Government for labor, subsistence, equipment, 
supplies, and transportation deemed necessary to control or suppress a 
fire set or caused by the Contractor or the Contractor's agents or 
employees.
    (b) Contractor's Responsibility for Notification in Case of Fire. 
The Contractor shall immediately notify the Government of any fires 
sighted on or in the vicinity of the work site.
    (c) Contractor's Responsibility for Responding to Emergencies. When 
directed by the Contracting Officer, the Contractor shall allow the 
Government to temporarily use employees and equipment from the work site 
for emergency work (anticipated to be restricted to fire fighting). An 
equitable adjustment for the temporary use of employees and equipment 
will be made under the Changes clause, FAR 52.243-4.

                             (End of clause)



Sec. 452.236-78  Forest Service Standard Specifications for Construction 
          of Roads and Bridges.

    As prescribed in 436.578, insert the following clause:

 Forest Service Standard Specifications for Contstruction of Roads and 
                           Bridges (NOV 1996)

    The Forest Service Standard Specifications for Construction of Roads 
and Bridges, ____ 199_ are included by reference. The requirements 
contained in these specifications are hereby made a part of this 
solicitation and any resultant contract.

                             (End of clause)



Sec. 452.236-79  Opted Timber Sale Road Requirements.

    As prescribed in 436.579, insert the following clause:

             Opted Timber Sale Road Requirements (NOV 1996)

    This contract is for the construction of timber sale road(s) which a 
timber purchaser has opted to have the Government construct. The 
Government is obligated to make these roads available to the timber 
purchaser by ___*. Failure to make these roads available by this date 
could result in Government liability for delay to the timber purchaser 
for which the Contractor might become liable should the Contractor fail 
to complete this contract within the specified and allowed contract 
time.

                             (End of clause)

    * Contracting Officer shall insert appropriate date.



Sec. 452.236-80  Firms Ineligible for Award--Construction.

    As prescribed in 436.670, insert the following clause:

           Firms Ineligible for Award--Construction (NOV 1996)

    The firm(s) and its subsidiaries or affiliates signatory to this 
contract shall be ineligible for award of any construction contract 
resulting from the design work performed under this contract.

                             (End of clause)



Sec. 452.237-70  Loss, Damage, Destruction or Repair.

    (a) As prescribed in 437.110(a), insert a clause substantially as 
follows:

[[Page 152]]

             Loss, Damage, Destruction or Repair (FEB 1988)

    (a) For equipment furnished under this contract without operator, 
the Government will assume liability for any loss, damage or destruction 
of such equipment, not to exceed a total of $___* except that no 
reimbursement will be made for loss, damage or destruction due to (1) 
ordinary wear or tear, (2) mechanical failure, or (3) the fault or 
negligence of the Contractor or the Contractor's agents or employees.
    (b) For equipment furnished under this contract with operator, the 
Government shall not be liable for any loss, damage or destruction of 
such equipment, except for loss, damage or destruction resulting from 
the negligent or wrongful act(s) of Government employee(s) while acting 
within the scope of their employment.
    (c) All repairs to equipment furnished under this contract shall be 
made by the Contractor and reimbursement, if any, shall be determined in 
accordance with (a) or (b) above. Repairs shall be made promptly and 
equipment returned to use within ___** hours. In lieu of repairing 
equipment, the Contractor may furnish similar replacement equipment 
within the time specified. The Contractor may authorize the Government 
to make repairs upon the request of the Contracting Officer. In such 
case, the Contractor will be billed for labor and parts costs.

                             (End of clause)

    * Contracting Officer shall insert amount available in current funds 
to cover potential liability.
    ** Contracting Officer shall insert appropriate number of hours.



Sec. 452.237-71  Pre-Bid/Pre-Proposal Conference.

    As prescribed in 437.110(b), insert a provision substantially as 
follows:

               Pre-Bid/Pre-Proposal Conference (FEB 1988)

    (a) The Government is planning a pre-bid/pre-proposal conference, 
during which potential offerors may obtain a better understanding of the 
work required.
    (b) Offerors are encouraged to submit all questions in writing at 
least five (5) days prior to the conference. Questions will be 
considered at any time prior to or during the conference; however, 
offerors will be asked to confirm verbal questions in writing. 
Subsequent to the conference, an amendment to the solicitation 
containing an abstract of the questions and answers, and a list of 
attendees, will be disseminated.
    (c) In order to facilitate conference preparations, it is requested 
that the person named on the Standard Form 33 of this solicitation be 
contacted and advised of the number of persons who will attend.
    (d) The Government assumes no responsibility for any expense 
incurred by an offeror prior to contract award.
    (e) Offerors are cautioned that, notwithstanding any remarks or 
clarifications given at the conference, all terms and conditions of the 
solicitation remain unchanged unless they are changed by amendment to 
the solicitation. If the answers to conference questions, or any 
solicitation amendment, create ambiguities, it is the responsibility of 
the offeror to seek clarification prior to submitting an offer.
    (f) The conference will be held:

Date:___________________________________________________________________
Time:___________________________________________________________________
Location:_______________________________________________________________

                             (End of clause)



Sec. 452.237-73  Equipment Inspection Visit.

    As prescribed in 437.110(c), insert the following provision:

                  Equipment Inspection Visit (FEB 1988)

    Offerors are urged and expected to inspect the equipment on which 
maintenance or repairs are to be performed and to satisfy themselves 
regarding all conditions that may affect the cost of contract 
performance, to the extent that the information is reasonably 
obtainable. In no event shall failure to inspect the equipment 
constitute grounds for a claim after contract award.
    Offerors are invited to inspect the ___* at ___* by telephoning ___* 
on ___* for an appointment.

                             (End of clause)

    * Contracting Officer shall insert appropriate data.



Sec. 452.237-74  Key Personnel.

    As prescribed in 437.110(d), insert a clause substantially as 
follows:

                        Key Personnel (FEB 1988)

    (a) The Contractor shall assign to this contract the following key 
personnel: _____
    (b) During the first ninety (90) days of performance, the Contractor 
shall make no substitutions of key personnel unless the substitution is 
necessitated by illness, death, or termination of employment. The 
Contractor shall notify the Contracting Officer within 15 calendar days 
after the occurrence of any of these events and provide the information 
required by paragraph (c) below. After the initial 90-day period, the 
Contractor shall submit the information required by paragraph

[[Page 153]]

(c) to the Contracting Officer at least 15 days prior to making any 
permanent substitutions.
    (c) The Contractor shall provide a detailed explanation of the 
circumstances necessitating the proposed substitutions, complete resumes 
for the proposed substitutes, and any additional information requested 
by the Contracting Officer. Proposed substitutes should have comparable 
qualifications to those of the persons being replaced. The Contracting 
Officer will notify the Contractor within 15 calendar days after receipt 
of all required information of the decision on substitutions. The 
contract will be modified to reflect any approved changes of key 
personnel.

                             (End of clause)



Sec. 452.237-75  Restrictions Against Disclosure.

    As prescribed in 437.110(e), insert a clause substantially as 
follows:

               Restrictions Against Disclosure (FEB 1988)

    (a) The Contractor agrees, in the performance of this contract, to 
keep all information contained in source documents or other media 
furnished by the Government in the strictest confidence. The Contractor 
also agrees not to publish or otherwise divulge such information in 
whole or in part in any manner or form, or to authorize or permit others 
to do so, taking such reasonable measures as are necessary to restrict 
access to such information while in the Contractor's possession, to 
those employees needing such information to perform the work provided 
herein, i.e., on a ``need to know'' basis. The Contractor agrees to 
immediately notify in writing, the Contracting Officer, named herein, in 
the event that the Contractor determines or has reason to suspect a 
breach of this requirement.
    (b) The Contractor agrees not to disclose any information concerning 
the work under this contract to any persons or individual unless prior 
written approval is obtained from the Contracting Officer. The 
Contractor agrees to insert the substance of this clause in any 
consultant agreement or subcontract hereunder.

                             (End of clause)



Sec. 452.237-76  Progress Reporting.

    As prescribed in 437.270(a), insert a clause substantially as 
follows:

                      Progress Reporting (FEB 1988)

    The Contractor shall submit a progress report ___*, covering work 
accomplished during that period of the contract performance. The 
progress report shall be brief and factual and shall be prepared in 
accordance with the following format:
    (a) A cover page containing:
    (1) Contract number and title;
    (2) Type of report, sequence number of report, and period of 
performance being reported;
    (3) Contractor's name and address;
    (4) Author(s); and
    (5) Date of report.
    (b) Section I--An introduction covering the purpose and scope of the 
contract effort. This shall be limited to one paragraph in all but the 
first and final month's narrative.
    (c) Section II--A description of overall progress plus a separate 
description of each task or other logical segment of work on which 
effort was expended during the report period. The description shall 
include pertinent data and/or graphs in sufficient detail to explain any 
significant results achieved.
    (d) Section III--A description of current technical or substantive 
performance, and any problem(s) which may impede performance along with 
proposed corrective action.
    (e) Section IV--A planning schedule shall be included with the first 
progress report for all assigned tasks required under the contract, 
along with the estimated starting and completion dates for each task. 
The planning schedule shall be updated and submitted with each 
subsequent technical progress report, including an explanation of any 
difference between actual progress and planned progress, why the 
differences have occurred, and--if behind planned progress--what 
corrective steps are planned.
    (f) Section V--If applicable, financial information shall be 
submitted for each major task or line item cost.
    Data shall include:
    (1) The total estimated cost budgeted (fee excluded).
    (2) The estimated cost expended during the current reporting period.
    (3) Identification of direct labor hours of prime contractor and 
subcontractor(s) and/or consultant(s), if applicable.
    (4) Total project to-date expenditures.
    (5) Total remaining funds.

                             (End of clause)

    * Contracting Officer shall insert frequency of reporting 
requirement.



Sec. 452.237-78  Contracts with Consulting Firms for Services.

    As prescribed in 437.270(b), insert a clause substantially as 
follows:

         Contracts with Consulting Firms for Services (FEB 1988)

    Offerors are specifically cautioned that any firm(s) receiving a 
contract award to

[[Page 154]]

provide the services described herein will be prohibited from competing 
for or receiving a follow-on contract to perform ___.*

                             (End of clause)

    * Contracting Officer shall insert the appropriate information.



Sec. 452.246-70  Inspection and Acceptance.

    As prescribed in 446.370, insert the following clause:

                  Inspection and Acceptance (FEB 1988)

    (a) The Contracting Officer or the Contracting Officer's duly 
authorized representative will inspect and accept the supplies and/or 
services to be provided under this contract.
    (b) Inspection and acceptance will be performed at: ___.*

                             (End of clause)

    * Contracting Officer shall insert appropriate identifying data.
    Alternate I (FEB 1988). As prescribed in 446.370, substitute a 
paragraph (b) and add a paragraph (c):
    (b) Inspection will be performed at: ___.*
    (c) Acceptance will be performed at: ___.*

                             (End of clause)



Sec. 452.247-70  Delivery Location.

    As prescribed in 447.302, insert a clause substantially as follows:

                      Delivery Location (FEB 1988)

    Shipment of deliverable items, other than reports, shall be to: 
___.*

                             (End of clause)

    * Contracting Officer shall insert appropriate identifying data.



Sec. 452.247-71  Marking Deliverables.

    As prescribed in 447.305-10(a), insert a clause substantially as 
follows:

                     Marking Deliverables (FEB 1988)

    (a) The contract number shall be placed on or adjacent to all 
exterior mailing or shipping labels of deliverable items called for by 
the contract.
    (b) Mark deliverables, except reports, for: ___.*

                             (End of clause)

    * Contracting Officer shall insert the appropriate information.



Sec. 452.247-72  Packing for Domestic Shipment.

    As prescribed in 447.305-10(b), insert the following clause:

                Packing for Domestic Shipment (FEB 1988)

    Material shall be packed for shipment in such a manner that will 
insure acceptance by common carriers and safe delivery at destination. 
Containers and closures shall comply with the Interstate Commerce 
Commission regulations, Uniform Freight Classification Rules, or 
regulations of other carriers as applicable to the mode of 
transportation.

                             (End of clause)



Sec. 452.247-73  Packing for Overseas Shipment.

    As prescribed in 447.305-10(c), insert the following clause:

                Packing for Overseas Shipment (FEB 1988)

    Supplies shall be packed for overseas shipment in accordance with 
the best commercial export practice suitable for water movement to 
arrive undamaged at ultimate destination.

                             (End of clause)

                             PART 453_FORMS

Sec.

Sec. 453.000  Scope of part.

                          Subpart 453.1_General


Sec. 453.103  Exceptions.

Sec. 453.108  Recommendations concerning forms.

                   Subpart 453.2_Prescription of Forms


Sec. 453.200  Scope of subpart.

Sec. 453.213  Simplified Acquisition and other simplified purchase 
          procedures (AD-838).

Sec. 453.270  Request for contract action (AD-700).

                  Subpart 453.3_Illustrations of Forms


Sec. 453.300  Scope of subpart.

Sec. 453.303  Agency forms.

Sec. 453.303-700  Procurement Request (AD-700).

Sec. 453.303-838  Purchase Order (AD-838).

    Authority: 5 U.S.C. 301 and 40 U.S.C. 486(c).

    Source: 61 FR 53646, Oct. 15, 1996, unless otherwise noted.



Sec. 453.000  Scope of part.

    This part:

[[Page 155]]

    (a) Prescribes USDA (AD) forms for use in acquisition,
    (b) Contains requirements and information generally applicable to AD 
forms and forms prescribed by FAR part 53, and
    (c) Illustrates AD forms.

                          Subpart 453.1_General



Sec. 453.103  Exceptions.

    (a) The contracting officer shall submit a request for exceptions to 
forms prescribed in FAR part 53 through the head of the contracting 
activity (HCA) to the Senior Procurement Executive (SPE) for referral to 
the GSA.
    (b) Requests for exceptions to AD forms prescribed in part 453 shall 
be handled as individual or class deviations, as appropriate (see 
subpart 401.4).



Sec. 453.108  Recommendations concerning forms.

    Contracting officers shall submit recommendations for new forms or 
to revise, eliminate, or consolidate forms prescribed by FAR part 53 and 
part 453 through the HCA to the SPE.

                   Subpart 453.2_Prescription of Forms



Sec. 453.200  Scope of subpart.

    This subpart prescribes USDA (AD) forms for use in acquisition. 
Consistent with the approach used in FAR subpart 53.2, this subpart is 
arranged by subject matter, in the same order as, and keyed to, the 
parts of the AGAR in which the form usage requirements are addressed.



Sec. 453.213  Simplified Acquisition and other simplified purchase 
          procedures (AD-838).

    Form AD-838, Purchase Order, is prescribed for use as a Simplified 
Acquisition Procedure/delivery order/task order document in lieu of OF 
347 and OF 348 (see 413.307).

[61 FR 53646, Oct. 15, 1996, as amended at 64 FR 45895, Aug. 23, 1999]



Sec. 453.270  Request for contract action (AD-700).

    Form AD-700, Procurement Request, may be used as a contract 
requisition document by contracting activities in USDA.

                  Subpart 453.3_Illustrations of Forms



Sec. 453.300  Scope of subpart.

    This subpart contains illustrations of USDA (AD) forms for use in 
acquisitions. Forms are not illustrated in the Federal Register or Code 
of Federal Regulations. Individual copies may be obtained from any USDA 
contracting activity or the office of the SPE.



Sec. 453.303  Agency forms.



Sec. 453.303-700  Procurement Request (AD-700).



Sec. 453.303-838  Purchase Order (AD-838).

[[Page 157]]



               CHAPTER 5--GENERAL SERVICES ADMINISTRATION




                           (Parts 500 to 599)

  --------------------------------------------------------------------

                          SUBCHAPTER A--GENERAL
Part                                                                Page
501             General Services Administration Acquisition 
                    Regulation System.......................         159
502             Definitions of words and terms..............         160
503             Improper business practices and personal 
                    conflicts of interest...................         161
504             Administrative matters......................         164
           SUBCHAPTER B--COMPETITION AND ACQUISITION PLANNING
505             Publicizing contract actions................         166
509             Contractor qualifications...................         167
511             Describing agency needs.....................         171
512             Acquisition of commercial items.............         173
          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
513             Simplified acquisition procedures...........         174
514             Sealed bidding..............................         174
515             Contracting by negotiation..................         180
516             Types of contracts..........................         186
517             Special contracting methods.................         188
                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
519             Small business programs.....................         190
522             Application of labor laws to Government 
                    acquisitions............................         191
523             Environment, conservation, occupational 
                    safety and drug-free workplace..........         192
525             Foreign acquisition.........................         192
             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
527             Patents, data, and copyrights...............         194

[[Page 158]]

528             Bonds and insurance.........................         194
529             Taxes.......................................         194
532             Contract financing..........................         195
533             Protests, disputes, and appeals.............         198
             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING
536             Construction and architect-engineer 
                    contracts...............................         200
537             Service contracting.........................         204
538             Federal supply schedule contracting.........         205
                    SUBCHAPTER G--CONTRACT MANAGEMENT
542             Contract administration and audit services..         207
543             Contract modifications......................         207
546             Quality assurance...........................         208
547             Transportation..............................         209
549             Termination of contracts....................         209
                     SUBCHAPTER H--CLAUSES AND FORMS
552             Solicitation provisions and contract clauses         211
553             Forms.......................................         272
               SUBCHAPTER I--SPECIAL CONTRACTING PROGRAMS
570             Acquiring leasehold interests in real 
                    property................................         273

[[Page 159]]



                          SUBCHAPTER A_GENERAL

 PART 501_GENERAL SERVICES ADMINISTRATION ACQUISITION REGULATION SYSTEM

               Subpart 501.1_Purpose, Authority, Issuance

Sec.

Sec. 501.101  Purpose.

Sec. 501.103  Authority.

Sec. 501.104  Applicability.

Sec. 501.105  Issuance.

Sec. 501.105-1  Publication and code arrangement.

Sec. 501.105-2  Arrangement of regulations.

Sec. 501.105-3  Copies.

Sec. 501.106  OMB approval under the Paperwork Reduction Act.

             Subpart 501.4_Deviations From the FAR and GSAR


Sec. 501.402  Policy.

Sec. 501.403  Individual deviations.

Sec. 501.404  Class deviations.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37203, July 9, 1999, unless otherwise noted.

               Subpart 501.1_Purpose, Authority, Issuance



Sec. 501.101  Purpose.

    (a) The General Services Acquisition Regulation (GSAR) contains 
agency acquisition policies and practices, contract clauses, 
solicitation provisions, and forms that control the relationship between 
GSA and contractors and prospective contractors.
    (b) GSAR address rules directly to you, the contracting officer, 
unless otherwise indicated.



Sec. 501.103  Authority.

    GSA's Senior Procurement Executive issues the GSAR under the 
authority of the Federal Property and Administrative Services Act of 
1949, as amended.



Sec. 501.104  Applicability.

    (a) General. The GSAR applies to contracts for suppliers or 
services, including construction.
    (b) Acquisition of leasehold interests in real property. Part 570 
establishes rules for the acquisition of leasehold interests in real 
property. Other provisions of 48 CFR chapter 5 (GSAR) do not apply to 
leases of real property unless specifically cross-reference in part 570.
    (c) Relationship to state. Some GSAR rules implement and interpret 
laws and other authorities affecting procurement. A GSAR rule 
specifically directed by statute has the force and effect of law.
    (d) GSAR/FAR Relationship. The GSAR may deviate from the Federal 
Acquisition Regulation (FAR) if authorized. If the GSAR does not 
implement the FAR, the FAR alone governs.



Sec. 501.105  Issuance.



Sec. 501.105-1  Publication and code arrangement.

    The GSAR is published in the following sources:
    (a) Daily issue of the Federal Register.
    (b) Annual Code of Federal Regulations (CFR), as Chapter 5 of Title 
48.
    (c) GSA Acquisition Manual distributed within GSA.
    (d) GSA Home Page at http://www/gas.gov. Click on either 
``Government Agencies'' or on ``Business and Industry,'' the click on 
``Acquisition.''



Sec. 501.105-2  Arrangement of regulations.

    (a) The GSAR numbers and captions policies and procedures to 
correspond to how they appear in the FAR, e.g., 1.104 in the FAR is 
501.104 in the GSAR.
    (b) GSAR rules not implementing the FAR have numbers beginning with 
70, e.g., part 570, subsection 515.209-70.
    (c) The GSAR may have gaps in its numbering scheme because a FAR 
rule may not require GSAR implementation.



Sec. 501.105-3  Copies.

    The GSAR in CFR form may be purchased from: Superintendent of 
Documents, Government Printing Office, Washington, DC 20402.



Sec. 501.106  OMB approval under the Paperwork Reduction Act.

------------------------------------------------------------------------
               GSAR Reference                      OMB Control No.
------------------------------------------------------------------------
509.105-1(a)...............................  3090-0007

[[Page 160]]

 
511.140-70.................................  3090-0203
511.204(d).................................  3090-0246
511.404(a)(1)..............................  3090-0204
511.404(a)(2)..............................  3090-0204
511.404(a)(5)..............................  3090-0204
514.201-7(a)...............................  3090-0200
516.203-4(a)(1)............................  3090-0243
516.506....................................  3090-0248
519.708(b).................................  3090-0252
522.406-6..................................  1215-0149
523.370....................................  3090-0205
532.111(c).................................  3090-0080
532.905-70.................................  9000-0102
532.905-71.................................  3090-0080
537.110(a).................................  3090-0197
537.110(b).................................  3090-0006
538.273(a)(1)..............................  3090-0250
538.273(a)(3)..............................  3090-0262
538.273(b)(1)..............................  3090-0121
542.1107...................................  3090-0027
546.307-70.................................  3090-0027
546.302-71.................................  3090-0027
549.502(b).................................  3090-0027
552.211-8..................................  3090-0204
552.211-77.................................  3090-0246
552.211-78.................................  3090-0204
552.211-82.................................  3090-0204
552.214-71.................................  3090-0200
552.216-70.................................  3090-0243
552.216-72.................................  3090-0248
552.216-73.................................  3090-0248
552.219-72.................................  3090-0252
552.223-72.................................  3090-0205
552.232-72.................................  3090-0080
552.237-70.................................  3090-0197
552.237-71.................................  3090-0006
552.238-70.................................  3090-0250
552.238-72.................................  3090-0262
552.238-74.................................  3090-0121
552.242-70.................................  3090-0027
552.246-70.................................  3090-0027
552.246-71.................................  3090-0027
552.249-71.................................  3090-0227
GSA-72-A...................................  3090-0121
GSA-527....................................  3090-0007
GSA-618-D..................................  1215-0149
GSA-1142...................................  3090-0080
GSA-1364...................................  3090-0086
GSA-1678...................................  3090-0027
GSA-2419...................................  9000-0102
570.702(c).................................  3090-0086
------------------------------------------------------------------------


[64 FR 37203, July 9, 1999, as amended at 65 FR 41378, July 5, 2000]

             Subpart 501.4_Deviations From the FAR and GSAR



Sec. 501.402  Policy.

    Uniformity is a goal of GSA's Acquisition Regulation System. Despite 
this desire for uniformity, a contracting activity may take any of the 
following actions:
    (a) Develop and test new procedures and techniques.
    (b) Adopt alternate procedures in the public interest for unique 
programmatic or managerial requirements
    (c) Deviate from a regulatory provision implementing a statutory 
requirement provided the deviation does not violate the underlying 
statute. Deviations must not be used to defeat the FAR and GSAR approval 
requirements.



Sec. 501.403  Individual deviations.

    (a) The Contracting Director approves individual deviations from the 
FAR and GSAR.
    (b) If GSA delegates authority to another agency and requires 
compliance with the GSAR as a condition of the delegation, the 
Contracting Director in the agency receiving the delegation may approve 
individual deviations from the GSAR unless the agency head receiving the 
delegation designates another official.
    (c) Send a copy of each deviation to GSA's Senior Procurement 
Executive (MV).



Sec. 501.404  Class deviations.

    (a) HCAs approve class deviations from the FAR and GSAR.
    (b) If GSA delegates authority to another agency and requires 
compliance with the GSAR as a condition of the delegation, the HCA in 
the agency receiving the delegation may approve class deviations from 
the GSAR unless the agency head receiving the delegation designates 
another official.
    (c) Send a copy of each deviation to GSA's Senior Procurement 
Executive (MV).
    (d) A request for class deviations must be supported by statements 
that fully describe the need for and the nature of the deviation.
    (e) Class deviations from the GSAR:
    (1) Expire in 12 months if not extended.
    (2) May be rescinded earlier by GSA's Senior Procurement Executive 
or by officials designated under paragraph (a) of this section without 
prejudice to any action taken previously.

                 PART 502_DEFINITIONS OF WORDS AND TERMS

    Authority: 40 U.S.C. 486(c).

[[Page 161]]


    Source: 64 FR 37204, July 9, 1999, unless otherwise noted.

                        Subpart 502.1_Definitions



Sec. 502.101  Definitions.

    Agency competition advocate means the GSA Competition Advocate in 
the Office of Acquisition Policy.
    Assigned counsel means the attorney employed by the Office of 
General Counsel (including offices of Regional Counsel) assigned to 
provide legal review or assistance.
    Contracting activity competition advocate means the individual 
designated in writing by the head of the contracting activity (HCA). 
This authority may not be redelegated. The HCA must ensure that the 
designated competition advocate is not assigned any duty or 
responsibility that is inconsistent with the advocacy function. The 
identity of the designated official shall be communicated to procuring 
staff and the Senior Procurement Executive.
    Contracting director means:
    (a) Except in FSS, a director of a Central Office or Regional office 
Division responsible for performing contracting or contract 
administration functions.
    (b) In FSS, a director of a Commodity Center or FSS Bureau.
    Contracting officer's representative (COR), contracting officer's 
technical representative (COTR), or contract administrator means a 
Government employee designated in writing by the contracting officer to 
perform specific limited activities for the contracting officer, such as 
contract administration.
    Debarring official or suspending official means the Senior 
Procurement Executive or a designee.
    Head of the contracting activity means the Deputy Associate 
Administrator for Acquisition Policy (MV); Commissioners of the Federal 
Technology Service (FTS); Federal Supply Service (FSS), or Public 
Buildings Service (PBS); or Regional Administrators. The Deputy 
Associate Administrator for Acquisition Policy serves as the HCA for 
Central Office contracting activities outside of FTS, FSS, and PBS.
    Senior procurement executive means the Deputy Associate 
Administrator for Acquisition Policy.
    Senior program official means a person reporting to, and designated 
by, the HCA to have overall program responsibility for determining how 
the agency will meet its need. The official should have a position of 
authority over the participating offices. Examples include Assistant 
Regional Administrators or Deputy Commissioners.

 PART 503_IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST

                        Subpart 503.1_Safeguards

Sec.

Sec. 503.104  Procurement integrity.

Sec. 503.104-3  Definitions.

Sec. 503.104-9  Contract clauses.

       Subpart 503.2_Contractor Gratuities to Government Personnel


Sec. 503.204  Treatment of violations.

                      Subpart 503.4_Contingent Fees


Sec. 503.404  Contract clause.

             Subpart 503.5_Other Improper Business Practices


Sec. 503.570  Advertising.

Sec. 503.570-1  Policy.

Sec. 503.570-2  Contract clause.

             Subpart 503.7_Voiding and Rescinding Contracts


Sec. 503.702  Definition.

Sec. 503.705  Procedures.

    Authority: 40 U.S.C. 486(c).

    Source: At 64 FR 37204, July 9, 1999, unless otherwise noted.

                        Subpart 503.1_Safeguards



Sec. 503.104  Procurement integrity.



Sec. 503.104-3  Definitions.

    Federal agency procurement as used in FAR 3.104 and in this section, 
also means acquisitions of leasehold interests in real property.



Sec. 503.104-9  Contract clauses.

          Acquisitions of Leasehold Interests in Real Property

    Insert a clause substantially the same as the clause at 552.203-70, 
Price

[[Page 162]]

Adjustment for Illegal or Improper Activity, in solicitations and 
contracts for and modifications to leasehold interests in real property 
exceeding $100,000.

       Subpart 503.2_Contractor Gratuities to Government Personnel



Sec. 503.204  Treatment of violations.

    (a) The Senior Procurement Executive, or designee, makes 
determinations under FAR 3.204.
    The Senior Procurement Executive, or designee, takes all the 
following actions:
    (1) Coordinates with legal counsel.
    (2) Initiates proceedings under FAR 3.204(a) by notifying the 
contractor that GSA is considering action against the contractor for a 
violation of the Gratuities clause. Notice is sent by a certified letter 
to the last known address of the party, its counsel, or agent for 
service of process. In the case of a business, notice is sent to any 
partner, principal officer, director, owner or co-owner, or joint 
venture.
    (3) Presumes receipt if no return receipt is received within 10 
calendar days after mailing the notice.
    (b) The contractor has 30 calendar days to exercise its rights under 
FAR 3.204(b), unless the Senior Procurement Executive, or designee, 
grants an extension.
    (c) If there is a dispute of fact material to making a 
determination, the Senior Procurement Executive, or designee, may refer 
the matter to an agency fact-finding official designated by the Chairman 
of the GSA Board of Contract Appeals. Referrals for fact-finding are not 
made in cases arising from a conviction or indictment as defined in FAR 
9.403. If a referral is made, the fact-finding official takes all the 
following actions:
    (1) Gives the contractor an opportunity to dispute material facts 
relating to the determinations under FAR 3.204(a)(1) and (2).
    (2) Conducts proceedings under rules consistent with FAR 3.204(b).
    (3) Schedules a hearing within 20 calendar days of receipt of the 
referral. The contractor or GSA may request an extension for good cause.
    (4) Delivers to the Senior Procurement Executive, or designee, 
written findings of fact (together with a transcription of the 
proceedings, if made) within 20 calendar days after the hearing record 
closes. The findings must resolve any material disputes of fact by a 
preponderance of the evidence.
    (d) The Senior Procurement Executive, or designee, may reject the 
findings of the fact-finding official only if the findings are clearly 
erroneous or arbitrary and capricious.
    (e) In cases arising from conviction or indictment, or in which 
there are no disputes of material fact, the Senior Procurement 
Executive, or designee, conducts the hearing required by FAR 3.204(b).
    (f) If the Gratuities clause was violated, the contractor may 
present evidence of mitigating factors to the Senior Procurement 
Executive, or designee, either orally or in writing, in accordance with 
a schedule the Senior Procurement Executive, or designee, establishes. 
The Senior Procurement Executive, or designee, exercises the 
Government's rights under FAR 3.204(c) only after considering mitigating 
factors.

                      Subpart 503.4_Contingent Fees



Sec. 503.404  Contract clause.

    Insert 552.203-5, Covenant Against Contingent Fees, in solicitations 
and contracts for the acquisition of leasehold interests in real 
property expected to exceed $100,000.

             Subpart 503.5_Other Improper Business Practices



Sec. 503.570  Advertising.



Sec. 503.570-1  Policy.

    GSA policy precludes contractors from referring to GSA contracts in 
commercial advertising in a manner that states or implies the Government 
approves or endorses the product or service or considers it superior to 
other products or services. The intent of this policy is to prevent the 
appearance of Government bias toward any product or service.

[[Page 163]]



Sec. 503.570-2  Contract clause.

    Insert the clause at 552.203-71, Restriction on Advertising, in 
solicitations and contracts, including acquisitions of leasehold 
interests in real property, if the contract amount is expected to exceed 
the simplified acquisition threshold.

             Subpart 503.7_Voiding and Rescinding Contracts



Sec. 503.702  Definition.

    Notice means a letter sent by certified mail with a return receipt 
requested to the last known address of a party, its counsel, or agent 
for service of process. In the case of a business, such notice may be 
sent to any partner, principal officer, director, owner or co-owner, or 
joint venturer. If no return receipt is received within 10 calendar days 
of mailing, receipt is presumed.
    Voiding and rescinding official means the Senior Procurement 
Executive or designee.



Sec. 503.705  Procedures.

    (a) Contracting officer's actions:
    (1) If a contract is tainted by misconduct, consult with assigned 
counsel to determine if the Government has a common law remedy such as 
avoidance, rescission, or cancellation.
    (2) If the contractor has a final conviction for a violation under 
18 U.S.C. 201-224, you may refer the matter to the voiding and 
rescinding official under FAR 3.705.
    (i) In the referral, identify the final conviction and include the 
information required by FAR 3.705(d)(2) through (5).
    (ii) Coordinate the referral with the Office of Inspector General to 
determine whether to recommend debarment.
    (3) You may postpone a decision to exercise the Government's common 
law right to void, rescind, or cancel a contract until completion of 
legal proceedings against the contractor.
    (b) Voiding and rescinding official's actions:
    (1) The voiding and rescinding official reviews the referral and 
coordinates with assigned counsel and the contracting activity.
    (2) If the official decides to declare void and rescind a contract 
and to recover the amounts expended and the property transferred, the 
official takes both the following actions:
    (i) Issues the notice required by FAR 3.705.
    (ii) Conducts the hearing contemplated by FAR 3.705(c)(3).
    (3) In case of a dispute of material fact about the agency decision, 
the official refers the matter to the fact-finding official designated 
by the Chairman of the GSA Board of Contract Appeals. The voiding and 
rescinding official makes this referral if the dispute of fact relates 
to any of the following:
    (i) Contracts affected by the final conviction.
    (ii) Amounts expended and property transferred by the Government 
under the affected contracts.
    (iii) Identity and value of any tangible benefits received by the 
Government under the affected contracts.
    (4) The voiding and rescinding official issues GSA's final decision 
under FAR 3.705(e) after receiving the fact-finding official's report, 
if a referral was made. The voiding and rescinding official may reject 
the fact-finding official's findings only if they are clearly erroneous 
or arbitrary and capricious.
    (5) The official coordinates the final decision was the contracting 
activity and provides the activity a copy of the decision.
    (c) Fact-finding official's actions: The fact-finding official takes 
all the following actions:
    (1) Gives the contractor an opportunity to dispute material facts.
    (2) Conducts the proceedings under rules consistent with FAR 
3.705(c)(3).
    (3) Schedules a hearing within 20 calendar days after receiving the 
referral. The official may grant extensions for good cause at the 
request of the contractor or GSA.
    (4) Delivers written findings of fact to the voiding and rescinding 
official (together with a transcription of the proceeding, if made) 
within 20 calendar days after the hearing record closes. The findings 
must resolve any material disputes of fact by a preponderance of the 
evidence.

[[Page 164]]

                     PART 504_ADMINISTRATIVE MATTERS

    Subpart 504.4_Safeguarding Classified Information Within Industry

Sec.

Sec. 504.402  General.

Sec. 504.475  Return of classified information.

            Subpart 504.5_Electronic Commerce in Contracting


Sec. 504.500  Scope of subpart.

Sec. 504.502  Policy.

Sec. 504.570  Procedures for using the EPS.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37205, July 9, 1999, unless otherwise noted.

    Subpart 504.4_Safeguarding Classified Information Within Industry



Sec. 504.402  General.

    (a) This subpart:
    (1) Prescribes procedures for safeguarding classified information 
required to be disclosed to contractors in connection with the 
solicitation of offers, and the award, performance, and termination of 
contracts.
    (2) Implements the requirements of the Department of Defense's 
Industrial Security Regulation (ISR) and Industrial Security Manual for 
Safeguarding Classified Information (ISM). By agreement, the Department 
of Defense (DOD) will act for, and on behalf of, GSA in rendering 
security services required for safeguarding classified information 
released by GSA to U.S. industry.
    (b) As used in this subpart, the term:
    (1) ``Contractor(s)'' means prospective contractors, subcontractors, 
vendors, and suppliers.
    (2) ``U.S. industry'' means those industries (including educational 
and research institutions) located within the United States, its 
possessions, and the Commonwealth of Puerto Rico.



Sec. 504.475  Return of classified information.

    (a) You must recover classified information unless it has been 
destroyed as provided in paragraph 19 of the ISM. The Government agency 
that provided classified information to a GSA contractor is responsible 
for the return of the information.
    (b) You must ensure that classified information furnished to 
prospective offerors, offerors, or contractors is returned immediately 
after any of the following:
    (1) After bid opening or closing date for receipt of proposals by 
non-responding offerors.
    (2) After contract award by unsuccessful offerors.
    (3) Upon termination or completion of the contract.
    (4) Upon notification that authorization to release classified 
information has been withdrawn.
    (5) After notification that a facility:
    (i) Does not have adequate means to safeguard classified 
information.
    (ii) Has had its security clearance revoked or inactivated.
    (6) Whenever otherwise instructed by the authority responsible for 
the security classification.

            Subpart 504.5_Electronic Commerce in Contracting



Sec. 504.500  Scope of subpart.

    This subpart provides policy and procedure for use of GSA's 
Electronic Posting System (EPS).



Sec. 504.502  Policy.

    (a) The EPS is GSA's primary vehicle for disseminating synopses and 
written solicitations. GSA intends that the EPS will substitute for, not 
supplement, paper copies of solicitations. (Note that FAR 2.101 defines 
``in writing'' or ``written'' to include ``electronically transmitted 
and stored information.'')
    (b) This policy does not apply to orders placed against existing 
contracts, including Federal Supply Service schedule contracts.
    (c) Nothing in this policy limits your authority to obtain oral 
quotations or proposals as authorized by regulation (e.g., FAR 13.106-1 
or FAR 15.203(f)).



Sec. 504.570  Procedures for using the EPS.

    (a) You must use the EPS to issue any synopsis required by FAR part 
5 or GSAR part 505.

[[Page 165]]

    (b) You must issue each written solicitation on the EPS, except as 
provided in paragraphs (c)(2) and (d) of this section.
    (c) Although GSA intends that the EPS will substitute for paper 
copies of solicitations, web-based transactions are not practical in 
some industries or in some geographic areas at this time.
    (1) If you expect that electronic access to a solicitation will 
result in adequate competition, distribute the solicitation only through 
the EPS. Include the following notice in the related synopsis:

    GSA is issuing this solicitation only electronically. Interested 
parties may access the solicitation at http://www.eps.gov. This site 
provides instructions for downloading the solicitation file.

    (2) If you believe that distribution of paper copies is necessary to 
ensure adequate competition, document the file to justify distribution 
of paper copies. Include the notice in paragraph (c)(1) of this section 
in the related synopsis, leaving out the first sentence.
    (d) In some cases, release of construction drawings must be 
controlled to ensure adequate security. In other cases, an exhibit or 
attachment incorporated in a solicitation may not be available 
electronically. In either of these cases, you must explain in both the 
synopsis and the solicitation how interested parties may obtain a copy. 
In addition to the notice required by paragraph (c), include a notice 
substantially the same as follows in both the synopsis and solicitation. 
Tailor the notice as necessary for the particular acquisition.

    This solicitation incorporates documents which are not available 
electronically. See [Identify the solicitation section that lists the 
subject documents]. Interested parties may request copies of these 
documents by writing the Contracting Officer at the address in [Identify 
address block in the solicitation].

    (e) The Electronic Posting System Manual provides detailed 
instructions for using the EPS. The Manual is available at http://
www.eps.gov/buyer.html.

[[Page 166]]



            SUBCHAPTER B_COMPETITION AND ACQUISITION PLANNING

                  PART 505_PUBLICIZING CONTRACT ACTIONS

               Subpart 501.1_Dissemination of Information

Sec.

Sec. 505.101  Methods of disseminating information.

           Subpart 505.2_Synopses of Proposed Contract Actions


Sec. 505.202  Exceptions.

Sec. 505.203  Publicizing and response time.

Sec. 505.270  Synopsis of amendments to solicitations.

                    Subpart 505.5_Paid Advertisements


Sec. 505.502  Authority.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37206, July 9, 1999, unless otherwise noted.

               Subpart 505.1_Dissemination of Information



Sec. 505.101  Methods of disseminating information.

    (a) In Regions with a Business Service Center (BSC), you may post 
the notice required by FAR 5.101(a)(2) at the BSC.
    (b) Use GSA's Electronic Posting System (EPS) to issue each synopsis 
required by FAR part 5 or GSAR part 505. When synopsizing a 
solicitation, include the appropriate notice(s) required by 504.570(c) 
and (d).
    (c) For acquisitions involving real property:

------------------------------------------------------------------------
                                                Then you must publicize
  If the acquisition is not exempt under FAR   the proposed acquisition--
         5.202 or GSAR 505.202, and--
------------------------------------------------------------------------
(1) The acquisition is for real property       (1) Either:
 appraisal services estimated to cost $25,000    (i) In local
 or more.                                       newspapers.
                                                 (ii) In the Commerce
                                                Business Daily through
                                                the EPS.
(2) The acquisition is for leasehold           (2) Either:
 interests in real property estimated to         (i) In local
 exceed 10,000 square feet (except lease        newspapers.
 construction on a preselected site).            (ii) In the Commerce
                                                Business Daily through
                                                the EPS.
(3) The acquisition is for a leasehold         (3) In the Commerce
 interest in a building to be constructed on    Business Daily through
 a preselected site.                            the EPS.
------------------------------------------------------------------------

    (d) You may publicize proposed leases of 10,000 square feet or less 
in local newspapers if it will serve to promote competition.

           Subpart 505.2_Synopses of Proposed Contract Actions



Sec. 505.202  Exceptions.

    The Administrator has determined under section 18(c)(3) of the 
Office of Federal Procurement Policy Act, as amended (41 U.S.C. 
416(c)(3)) and Section 8(g)(3) of the Small Business Act, as amended (15 
U.S.C. 644(g)(3)) that:
    (a) Synopsizing in the CBD is not always appropriate for 
acquisitions of leasehold interests in real property (except lease 
construction on a designated site) or real property appraisal 
services.Your may publicize such contract actions following the 
procedures in 505.101 and 505.203.
    (b) It is not appropriate or reasonable to publish an advance notice 
of any of the following:
    (1) Acquisitions of works of art, including the design, execution 
and installation of the artwork, under the Art-in-Architecture Program.
    (2) Supplemental agreements to leases of real property involving any 
of the following:
    (i) Expansion requests within the scope of a lease (see 570.403).
    (ii) Lease extensions under the conditions defined in 570.405.
    (iii) Building alterations within the scope of a lease (see 570.5).

[[Page 167]]



Sec. 505.203  Publicizing and response time.

    (a) If you publicize in local newspapers under 505.101(c), ensure 
that the notice appears in local newspapers at least 3 calendar days 
before issuance of the solicitation. Except as provided in paragraph (B) 
of this section, allow at least these minimum response times:
    (1) For leasehold interests in real property, 20 calendar days 
between solicitation issuance and the date established for receipt of 
initial offers.
    (2) For real property appraisal services valued at less than either 
the Trade Agreements Act (TAA) threshold or the North American Free 
Trade Agreement (NAFTA) threshold, 10 calendar days between solicitation 
issuance and the date established for receipt of initial offers. The 
lower of the two thresholds governs.
    (3) For real property appraisal services valued at or over the TAA 
threshold or the NAFTA threshold, 40 calendar days from when the notice 
appears to receipt of initial offers. If the acquisition falls in a 
general category identified in an annual forecast, the period may be 
reduced to as few as 10 days. The lower of the two thresholds governs.
    (b) The following exceptions to the publicizing and response times 
in paragraph (a) of this section apply only to proposed acquisitions of 
leasehold interests in real property:
    (1) For a proposed acquisition conducted using simplified lease 
acquisition procedures (see 570.2), consider the individual acquisition 
and establish a reasonable response time.
    (2) In cases of urgency, provide as much time as possible and 
document the file.



Sec. 505.270  Synopsis of amendments to solicitations.

    Synopsize in the CBD any solicitation amendment when the amendment 
either:
    (a) Increases the anticipated value of the proposed acquisition 
above the dollar threshold requiring synopsis.
    (b) Alters the scope of the proposed acquisition so that increased 
interest of contractors can be reasonably anticipated.

                    Subpart 505.5_Paid Advertisements



Sec. 505.502  Authority.

    (a) Newspapers. The HCA, or designee, must approve publication of 
paid newspaper advertisements. Approval is not required if FAR 5.101 or 
505.101 requires publication. Document the contract file with the 
regulatory citation or written approval to support the use of paid 
newspaper advertisements.
    (b) Other media. Advance approval is not required to advertise in 
other media.

                   PART 509_CONTRACTOR QUALIFICATIONS

            Subpart 509.1_Responsible Prospective Contractors

Sec.

Sec. 509.105  Procedures.

Sec. 509.105-1  Obtaining information.

Sec. 509.105-2  Determinations and documentation.

Sec. 509.106  Preaward surveys.

Sec. 509.106-2  Requests for preaward surveys.

                Subpart 509.2_Qualifications Requirements


Sec. 509.206  Acquisitions subject to qualification requirements.

Sec. 509.206-2  Contract clause.

            Subpart 509.3_First Article Testing and Approval


Sec. 509.306  Solicitation requirements.

Sec. 509.308  Contract clauses.

Sec. 509.308-1  Testing performed by the contractor.

Sec. 509.308-2  Testing performed by the Government.

         Subpart 509.4_Debarment, Suspension, and Ineligibility


Sec. 509.401  Applicability.

Sec. 509.403  Definitions.

Sec. 509.405  Effect of listing.

Sec. 509.405-1  Continuation of current contracts.

Sec. 509.405-2  Restrictions on subcontracting.

Sec. 509.406  Debarment.

Sec. 509.406-1  General.

Sec. 509.406-3  Procedures.

Sec. 509.407  Suspension.

Sec. 509.407-1  General.

Sec. 509.407-3  Procedures.

    Authority: 40 U.S.C. 486(c).

[[Page 168]]


    Source: 64 FR 37207, July 9, 1999, unless otherwise noted.

            Subpart 509.1_Responsible Prospective Contractors



Sec. 509.105  Procedures.



Sec. 509.105-1  Obtaining information.

    (a) From a prospective contractor. In making a determination of 
responsibility, you may use the GSA Form 527, Contractor's Qualification 
and Financial Information, to obtain information regarding financial 
capability from a prospective contractor.
    (b) From Government personnel. Solicit and consider information from 
all appropriate activities, including legal counsel, quality control, 
contract management, credit and finance, and the auditor before 
determining that an offeror is responsible. ``Auditor'' is either:
    (1) The Assistant Inspector General for Auditing (Central Office 
only).
    (2) The Regional Inspector General for Auditing.
    (3) Chief, Credit and Finance Section, the Heartland Region (for an 
evaluation of a prospective contractor's financial competence and 
credit).



Sec. 509.105-2  Determinations and documentation.

    (a) Provide written notification to a prospective contractor you 
determine not responsible. Include the basis for the determination. 
Notification provides the prospective contractor with the opportunity to 
correct any problem for future solicitation.
    (b) Due to the potential for de facto debarment, avoid making 
repeated determinations of nonresponsiblity based on the same past 
performance information.
    (c) To provide for timely consideration of the need to institute 
action to debar a contractor, submit a copy of each nonresponsibility 
determination, other than those based on capacity or financial 
capability, to the debarring official.



Sec. 509.106  Preaward surveys.



Sec. 509.106-2  Requests for preaward surveys.

    Federal Supply Service (FSS). Contracting activities in FSS may use 
GSA Form 353, Performance Evaluation & Facilities Report, in lieu of SF 
1403 through 1406. Complete Section I in accordance with instructions in 
553.370-353-I.

                Subpart 509.2_Qualifications Requirements



Sec. 509.206  Acquisitions subject to qualification requirements.



Sec. 509.206-2  Contract clause.

    Insert 552.209-70, Product Removal from Qualified Products List, in 
solicitations and contracts containing FAR 52.209-1, Qualification 
Requirements.

            Subpart 509.3_First Article Testing and Approval



Sec. 509.306  Solicitation requirements.

    (a) The clauses at FAR 52.209-3 and 52.209-4 do not cover all the 
solicitation requirements described in FAR 9.306. If a solicitation 
contains a testing and approval requirement, you must address the 
requirements in FAR 9.306 (d), (f), (g), (h), (i), and (j). For FSS, the 
clauses prescribed in 509.308 address the requirement in FAR 9.306(h).
    (b) In FSS solicitations that contain FAR 52.209-3, First Article 
Approval--Contractor Testing, or FAR 52.209-4, First Article Approval--
Government Testing, insert 552.209-71, Waiver of First Article Testing 
and Approval Requirement.



Sec. 509.308  Contract clauses.



Sec. 509.308-1  Testing performed by the contractor.

    In FSS solicitations and contracts that will require the contractor 
to perform testing, insert 552.209-72, Supplemental Requirements for 
First Article Approval--Contractor Testing, and FAR 52.209-3, Alternate 
I.

[[Page 169]]



Sec. 509.308-2  Testing performed by the Government.

    In FSS solicitations and contracts that will have the Government 
responsible for first article testing, insert 552.209.73, Supplemental 
Requirements for First Article Approval--Government Testing, and FAR 
52.209-4, Alternate I.

         Subpart 509.4_Debarment, Suspension, and Ineligibility



Sec. 509.401  Applicability.

    This subpart applies to all the following:
    (a) Acquisitions of personal property, nonpersonal services 
(including construction), space in buildings, transportation services 
(Federal Property Management Regulations (FPMR) Subpart 101-40.4).
    (b) The purchase, sale, and disposal of real property.
    (c) Contracts for disposal of personal property (FPMR Subpart 101-
45.6).
    (d) Covered transactions as defined at General Services Property 
Management Regulations (GSPMR) 105-68.110(a).



Sec. 509.403  Definitions.

    Fact-finding official, means the Chairman of the Debarment and 
Suspension Board within the GSA Board of Contract Appeals or a designee.
    Notice means a letter sent by certified mail, return receipt 
requested, to the last known address of a party, its counsel, or agent 
for service of process. In the case of a business, such notice may be 
sent to any partner, principal officer, director, owner or co-owner, or 
joint venturer. If no return receipt is received within 10 calendar days 
of mailing, receipt will then be presumed.



Sec. 509.405  Effect of listing.



Sec. 509.405-1  Continuation of current contracts.

    (a) Consider terminating a current contract under any of the 
following circumstances:
    (1) Any of the circumstances giving rise to the debarment or 
suspension also constitute a default in the contractor's performance of 
the contract.
    (2) The contractor presents a significant risk to the Government in 
completing the contract.
    (3) The conduct that provides the cause of the suspension, proposed 
debarment, or debarment involved a GSA contract.
    (b) Determine which of the following is in the Government's best 
interest:
    (1) Terminate the contract for either convenience or cause.
    (2) Cancel under appropriate contract clauses (e.g., 552.238-73, 
Cancellation).
    (3) Use other available alternatives under:
    (i) FAR 3.2 and 503.2.
    (ii) FAR 3.7 and 503.7.
    (c) Before making a decision, consult with legal counsel and 
consider these factors:
    (1) Seriousness of the cause for debarment or suspension.
    (2) Extent of contract performance.
    (3) Potential costs of termination and reprocurement.
    (4) Need for or urgency of the requirement, contract coverage, and 
the impact of delay for reprocurement.
    (5) Availability of other safeguards to protect the Government's 
interest until completion of the contract.
    (6) Availability of alternate competitive sources to meet the 
requirement (e.g., other multiple award contracts, readily available 
commercial items, etc.).
    (d) The debarring official is the designee under FAR 9.405-1(c).



Sec. 509.405-2  Restrictions on subcontracting.

    The debarring official is the designee under FAR 9.405-2(a).



Sec. 509.406  Debarment.



Sec. 509.406-1  General.

    The debarring official is the designee under FAR 9.406-1(c).



Sec. 509.406-3  Procedures.

    (a) Investigation and referral.
    (1) Refer to the debarring official matters involving serious 
contract improprieties or performance deficiencies. Performance 
deficiencies that continue over a period of time or apply to more than 
one contract may warrant debarment consideration.

[[Page 170]]

    (2) Refer possible criminal or fraudulent activities to the Office 
of the Inspector General (OIG). See 5 CFR 6701.107, Reporting Waste, 
Fraud, Abuse, and Corruption. If, after investigation, the OIG believes 
a cause for debarment exists, it will refer the matter to the debarring 
official for consideration of debarment action.
    (b) Reports. Include in referrals to the debarring official a report 
that contains at least the following:
    (1) The recommendation and supporting rationale.
    (2) A list of parties to be considered for possible debarment, 
including the contractor, principals, and affiliates. Include last known 
home and business addresses, zip codes, and DUNS Number.
    (3) A statement of facts.
    (4) Copies of documentary evidence and a list of witnesses. Include 
addresses and telephone numbers. Determine their availability to appear 
at a fact-finding proceeding and identify the subject matter of their 
testimony.
    (5) GSA's acquisition history with the contractor. Include recent 
experience, copies of the pertinent contracts, and an explanation of 
impact debarment would have on GSA programs. OIG referrals do not 
require this explanation; the debarring official will obtain the 
information directly from the contracting activity(s).
    (6) A list of any known active or potential criminal investigations, 
criminal or civil proceedings, or administrative claims before the Board 
of Contract Appeals.
    (7) A statement regarding the impact of the debarment action on GSA 
programs. This statement is not required for referrals by the Inspector 
General; the debarring official will obtain a statement directly from 
the contracting activity(s).
    (c) Review. The debarring official will review the report, and after 
coordinating with assigned legal counsel, either:
    (1) Initiate debarment action.
    (2) Decline debarment action.
    (3) Request additional information.
    (4) Refer the matter to the OIG for further investigation and 
development of a case file.
    (d) Decisionmaking process.
    (1) The debarring official will provide:
    (i) Notice of declinations, proposed debarments, and decisions to 
the referring activity.
    (ii) Notice of proposed debarment to each party being considered for 
debarment.
    (iii) Decision notices to each party after considering information 
in the administrative record and information and argument submitted by 
the affected party or parties.
    (2) A party proposed for debarment:
    (i) Has 30 calendar days after receipt of the notice to respond to 
the debarring official or the debarment becomes final.
    (ii) May request and receive a copy of the administrative record 
that was the basis for the proposed debarment. If information is 
withheld, the party will be notified and provided the reason.
    (iii) May request the opportunity to present information and 
argument in person to the debarring official. The debarring official 
will schedule an oral presentation within 20 calendar days of receipt of 
the request, unless a longer period of time is requested by the party. 
An oral presentation is informal and a transcript usually is not made. 
The party may supplement the oral presentation with written information 
and arguments.
    (iv) May identify to the debarring official material facts in 
dispute and the bases. For an action other than one based on a 
conviction of civil judgment, a party may request review and a written 
finding by a fact-finding official.
    (3) The debarring official will determine whether there is a genuine 
dispute of material fact. If so, the debarring official refers the 
matter to a fact-finding official, who will take the following action as 
appropriate:
    (i) Schedule a hearing within 20 calendar days after receipt of a 
request to resolve disputed facts.
    (ii) Grant extensions for good cause.
    (iii) Provide notice of scheduled hearing.
    (iv) Conduct hearings under rules consistent with FAR 9.406-3(b)(2).
    (v) Resolve facts in dispute and provide the debarring official with 
written

[[Page 171]]

findings of fact based on a preponderance of the evidence. The fact-
finding official provides the written findings of fact (together with a 
transcription of the proceeding, unless waived) within 20 calendar days 
after the hearing record closes.



Sec. 509.407  Suspension.



Sec. 509.407-1  General.

    The suspending official is the designee under FAR 9.407-1(d).



Sec. 509.407-3  Procedures.

    (a) General. The procedures in 509.406-3 apply to suspension actions 
except as noted in paragraph (b) of this section.
    (b) Fact-finding.
    (1) Fact-finding will not be conducted in an action:
    (i) Based on an indictment.
    (ii) When the suspending official finds no genuine dispute of 
material facts.
    (2) If the action is not based on an indictment, the suspending 
official must coordinate with the Department of Justice or state 
prosecutorial authority through OIG. Based on the advice received, the 
suspending official will determine if fact-finding would impair 
substantial interests of the Federal or state Government. In an action 
not based on an indictment, a suspended party may:
    (i) Identify to the suspending official material facts in dispute 
and the bases.
    (ii) Request review and a written finding by a fact-finding official 
to resolve genuine disputes of material fact. For procedures involving a 
genuine dispute of material fact, see 509.406-3(d)(3).

                    PART 511_DESCRIBING AGENCY NEEDS

      Subpart 511.1_Selecting and Developing Requirements Documents

Sec.

Sec. 511.104  Use of brand name or equal purchase descriptions.

Sec. 511.104-70  Solicitation provisions.

       Subpart 511.2_Using and Maintaining Requirements Documents


Sec. 511.204  Solicitation provisions and contract clauses.

             Subpart 511.4_Delivery or Performance Schedules


Sec. 511.404  Contract clauses.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37209, July 9, 1999, unless otherwise noted.

      Subpart 511.1_Selecting and Developing Requirements Documents



Sec. 511.104  Use of brand name or equal purchase descriptions.



Sec. 511.104-70  Solicitation provisions.

    (a) Include the following immediately after each brand name or equal 
item description, with instructions for the offeror to complete the 
information:

    Offering on:

Manufacturer's Name_____________________________________________________
Brand___________________________________________________________________
Model or Part No._______________________________________________________

    (b) If the solicitation does not require samples for ``or equal'' 
offers, include the following notice in the list of brand name or equal 
items or component parts:

                                 Notice

    If you offer other than brand name items identified in this 
solicitation, you must provide adequate information for GSA to determine 
the quality of the product(s) offered.

    (c) If you use brand name or equal purchase descriptions for some 
component parts of an end item, you may limit the application of the 
provision at FAR 52.211-6 to the specified components

[64 FR 37209, July 9, 1999. Redesignated and amended at 65 FR 41378, 
July 5, 2000]

       Subpart 511.2_Using and Maintaining Requirements Documents



Sec. 511.204  Solicitation provisions and contract clauses.

    (a) Construction services. Insert the clause at 552.211-71, Standard 
References, in solicitations and contracts for construction services 
when you expect the contract amount to exceed the simplified acquisition 
threshold, and

[[Page 172]]

the solicitation meets either of the following conditions:
    (1) The solicitation cites documents or publications not furnished 
with the solicitation.
    (2) The solicitation incorporates documents or publications by 
reference.
    (b) Federal specifications. Insert the clause at 552.211-72, 
Reference to Specifications in Drawings, in solicitations and contracts 
citing Federal specifications which contain drawings.
    (c) Supply contracts that exceed the simplified acquisition 
threshold. (1) Include the clause at 552.211-73, Marking, in 
solicitations and contracts for supplies when deliveries may be made to 
both civilian and military activities and the contract amount is 
expected to exceed the simplified acquisition threshold.
    (2) Include the clause at 552.211-74, Charges for Marking, in 
solicitations and contracts that include the clause at 552.211-73 or a 
similar clause.
    (3) Include the clause at 552.211-75, Preservation, Packaging and 
Packing, in solicitations and contracts for supplies expected to exceed 
the simplified acquisition threshold. You may also include the clause in 
contracts estimated to be at or below the simplified acquisition 
threshold when appropriate.
    (4) Insert a clause substantially the same as the clause at 552.211-
76, Charges for Packaging and Packing, in solicitations and contracts 
for supplies to be delivered to GSA distribution centers.
    (d) Supply contracts. Include the clause at 552.211-77, Packing 
List, in solicitations and contracts for supplies, including purchases 
over the micropurchase threshold.

             Subpart 511.4_Delivery or Performance Schedules



Sec. 511.404  Contract clauses.

    (a) Supply contracts.--(1) Single award schedules. Insert 552.211-8, 
Time of Delivery, in solicitations and contracts instead of the clause 
at FAR 52.211-8. If you need to show different delivery times for 
different items or groups of items, use Alternate I.
    (2) Multiple award schedules. Insert 552.211-78, Commercial Delivery 
Schedule (Multiple Award Schedule), in solicitations issued and 
contracts awarded under the multiple award schedule program.
    (3) Shelf-life items. Use the following clauses in solicitations and 
contracts that require delivery of shelf-life items within a specified 
number of months from the date of manufacture or production (see 101-
27.206-2 of the Federal Property Management Regulation):
    (i) Insert 552.211-79, Acceptable Age of Supplies, if the required 
shelf-life period is 12 months or less, and lengthy acceptance testing 
may be involved. For items having a limited shelf-life, substitute 
Alternate I when required by the director of the commodity center 
concerned.
    (ii) Insert 552.211-80, Age on Delivery, if the required shelf-life 
period is more than 12 months, or when source inspection can be 
performed within a short time period.
    (4) Stock replenishment contracts. Insert 552.211-81, Time of 
Shipment, in solicitations and stock replenishment contracts that do not 
include the Availability for Inspection, Testing and Shipment/Delivery 
clause at 552.211-83 and require shipment within 45 calendar days after 
receipt of the order. If shipment is required in more than 45 days, use 
Alternate I.
    (5) Notice of shipment. Include 552.211-82, Notice of Shipment, in 
solicitation and contracts for supplies when you need to have a notice 
of shipment from the contractor.
    (6) Indeterminate testing time. Insert 552.211-83, Availability for 
Inspection, Testing and Shipment/Delivery, in solicitations and 
contracts that provide for source inspection by Government personnel and 
that require lengthy testing for which time frames cannot be determined 
in advance. If the contract is for stock items, use Alternate I.
    (b) Construction contracts. Insert the clause at 552.211-84, Non-
Compliance with Contract Requirements, in solicitations and contracts 
for construction when you expect the contract amount to exceed the 
simplified acquisition threshold.

[[Page 173]]

                PART 512_ACQUISITION OF COMMERCIAL ITEMS

    Authority: 40 U.S.C. 486(c).

   Subpart 512.3_Solicitation Provisions and Contract Clauses for the 
                     Acquisition of Commercial Items



Sec. 512.301  Solicitation provisions and contract clauses for the 
          acquisition of commercial items.

    (a) Solicitation provisions and clauses. Insert these provisions or 
clauses in solicitations or solicitations and contracts, respectively, 
in accordance with the instructions provided:
    (1) 552.212-70, Preparation of Offer (Multiple Award Schedule), in 
solicitations and contracts issued under the multiple award schedule 
program.
    (2) 552.213-71, Contract Terms and Conditions Applicable to GSA 
Acquisition of Commercial Items, when listed clauses apply. The clause 
provides for incorporation by reference of terms and conditions which 
are, to the maximum extent practicable, consistent with customary 
commercial practice. If necessary, tailor this clause.
    (3) 552.212-72, Contract Terms and Conditions Required to Implement 
Statutes or Executive Orders Applicable to GSA Acquisitions of 
Commercial Items, when listed clauses apply. The clause provides for the 
incorporation by reference of terms and conditions required to implement 
provisions of law or executive orders that apply to commercial item 
acquisitions.
    (4) 552.213-73, Evaluation-Commercial Items (Multiple Award 
Schedule), in multiple award schedule solicitations. Use this provision 
instead of FAR 52.212-2.
    (b) Use of required provisions and clauses. Use only those 
provisions and clauses prescribed in this part. Unless the use of a 
provision or clause prescribed elsewhere in the GSAR is consistent with 
customary commercial practice for the item being acquired, disregard 
contrary instructions. Provisions and clauses prescribed in this part 
will be revised to reflect the applicability of new statutes and 
executive orders.
    (c) Discretionary use of GSAR provisions and clauses. Consistent 
with the limitations contained in FAR 12.302(c), include in 
solicitations and contracts by addendum other GSAR provisions and 
clauses.
    (d) Use of additional provisions and clauses. The Senior Procurement 
Executive must approve the use of a provision or clause that is either 
not:
    (1) Prescribed in the FAR or GSAR for use in contracts for 
commercial items.
    (2) Consistent with customary commercial practice.

[64 FR 37210, July 9, 1999, as amended at 65 FR 41378, July 5, 2000]

[[Page 174]]



           SUBCHAPTER C_CONTRACTING METHODS AND CONTRACT TYPES

               PART 513_SIMPLIFIED ACQUISITION PROCEDURES

              Subpart 513.3_Simplified Acquisition Methods

Sec.

Sec. 513.302  Purchase orders.

Sec. 513.302-70  Purchase order and related forms.

Sec. 513.303  Blanket purchase agreements (BPAs).

Sec. 513.303-3  Preparation of BPAs.

Sec. 513.307  Forms.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37211, July 9, 1999, unless otherwise noted.

              Subpart 513.3_Simplified Acquisition Methods



Sec. 513.302  Purchase orders.



Sec. 513.302-70  Purchase order and related forms.

    (a) See GSA Order, Guidance on Use of the Credit Card for Purchases 
(CFO 4200.1), for forms required for purchase card actions.
    (b) Use GSA Form 3000 or 300-1 (pin-feed format), Order for Supplies 
and Services, instead of OF 347, Order for Supplies or Services, when 
making purchases payable through the National Electronic Accounting and 
Reporting (NEAR) System.
    (1) This form may also be used to make other purchases when a 
specific form is not prescribed. It may be used as a delivery or task 
order instead of SF 1449, Solicitation/Contract/Order for Commercial 
Items.
    (2) Prepare and process GSA Form 300 following the instructions at 
553.370-300-I. Use GSA Form 300A or 300-A(1) (pin-feed format), order 
for Supplies or Services (continuation), if additional space is needed.
    (c) Use GSA Form 1458, Motor Vehicle Shop Work Order, Repair and 
Purchase Order, instead of the OF 347 when making purchases in 
connection with the maintenance, servicing or repair of GSA fleet 
management vehicles.
    (d) Use GSA Form 3186, Order for Supplies or Services or GSA Form 
3186-B, Order for Supplies or Services (EDI), instead of OF 347, Order 
for Supplies or Services, when making simplified acquisitions or placing 
orders against established contracts through the FSS-19 system.
    (1) Use GSA Form 3186 for mail orders placed against established 
contracts.
    (2) Document the file for a delivery, task, or purchase order 
transmitted to contractors electronically using Electronic Data 
Interchange (EDI) procedures by generating a GSA Form 3186-B.
    (e) Use GSA Form 8002B, Motor Vehicle Delivery Order, to order fleet 
management vehicles. Do not use this form as a purchase order for 
simplified acquisitions. Use GSA Form 8002A to notify the consignee of 
the status of motor vehicle requisitions.

[64 FR 37211, July 9, 1999, as amended at 65 FR 11247, Mar. 2, 2000]



Sec. 513.303  Blanket purchase agreements (BPAs).



Sec. 513.303-3  Preparation of BPAs.

    (a) Description of agreement. Describe limitations, if any, on the 
geographic area to be served.
    (b) Delivery tickets. Instruct the contractor to include the name of 
the individual placing the order on the delivery ticket. The individual 
receiving the item or service must sign and date the delivery or service 
ticket. Both the supplier and the receiving office must retain a copy of 
the delivery ticket.



Sec. 513.307  Forms.

    You may use the GSA Form 3521, Blanket Purchase Agreement, to 
prepare a blanket purchase agreement.

                         PART 514_SEALED BIDDING

                   Subpart 514.2_Solicitation of Bids

Sec.

Sec. 514.201  Preparation of invitations for bids.

Sec. 514.201-1  Uniform contract format.

Sec. 514.201-2  Part I--The Schedule.

Sec. 514.201-6  Solicitation provisions.

[[Page 175]]


Sec. 514.201-7  Contract clauses.

Sec. 514.202  General rules for solicitation of bids.

Sec. 514.202-4  Bid samples.

Sec. 514.203  Methods of soliciting bids.

Sec. 514.203-1  Transmittal to prospective bidders.

Sec. 514.270  Aggregate awards.

Sec. 514.270-1  Definition.

Sec. 514.270-2  Guidelines for use.

Sec. 514.270-3  Evaluation factors for award.

Sec. 514.270-4  Grouping line items for aggregate award.

Sec. 514.270-5  Evaluation methodologies for aggregate awards.

Sec. 514.270-6  Guidelines for using the weight factors method.

Sec. 514.270-7  Guidelines for using the price list method.

           Subpart 514.4_Opening of Bids and Award of Contract


Sec. 514.407  Mistakes in bids.

Sec. 514.407-3  Other mistakes disclosed before award.

Sec. 514.407-4  Mistakes after award.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37211, July 9, 1999, unless otherwise noted.

                   Subpart 514.2_Solicitation of Bids



Sec. 514.201  Preparation of invitations for bids.



Sec. 514.201-1  Uniform contract format.

    Include the following notice in each solicitation:

    The information collection requirements contained in this 
solicitation/contract, are either required by regulation or approved by 
the Office of Management and Budget pursuant to the Paperwork Reduction 
Act and assigned OMB Control No. 3090-0162.



Sec. 514.201-2  Part I--The Schedule.

    (a) When you use Standard Form 33, Solicitation, Offer and Award, 
include the following cautionary notice:

    Notice to Bidders--Use Item 13 of the Standard Form 33, 
Solicitation, Offer and Award, to offer prompt payment discounts. The 
Prompt Payment clause of this solicitation sets forth payment terms. Do 
not insert any statement in Item 13 which requires payment sooner than 
the time stipulated in the Prompt Payment clause. Example: If you insert 
``NET 20'' in Item 13, GSA will reject your offer as nonresponsive 
because the entry contradicts the 30 day payment terms specified in the 
Prompt Payment clause.

    (b) When you use any other authorized form (e.g., Standard Form 
1447, Solicitation/Contract), include the notice in paragraph (a) of 
this section. Change the reference to the form number, form title, and 
item number accordingly.



Sec. Sec. 514.201-6  Solicitation provisions.

    When you will consider all or none bids, insert the provision at 
552.214-70, ``All or None'' Offers, in the solicitation. For 
requirements or indefinite quantity contracts, use Alternate I. Do not 
include this provision in solicitations when you require the bidder to 
submit bids on all items and will make only one award.



Sec. 514.201-7  Contract clauses.

    (a) Stock replenishment contracts. For some stock replenishment 
contracts, individual contractors may be unable to furnish the 
Government's monthly requirements. You may determine that progressive 
awards will be more expedient. In such cases, insert a clause 
substantially the same as the clause 552.214-71, Progressive Awards and 
Monthly Quantity Allocations, in the solicitation and contract.
    (b) Examinations of Records. (1) Insert 552.214-70, Examination of 
Records by GSA, in solicitations and contracts for supplies or services 
that exceed $100,000, and acquisitions of leasehold interests in real 
property that exceed the simplified lease acquisition threshold, that 
meet at least one of the following conditions:
    (i) Involve the use or disposition of Government-furnished property.
    (ii) Provide for advance payments, progress payments based on cost, 
or guaranteed loan.
    (iii) Contain a price warranty or price reduction clause.
    (iv) Include an economic price adjustment clause where the 
adjustment is not based solely on an established, third party index.
    (v) Are requirements, indefinite-quantity, or letter contracts as 
defined in FAR part 16.
    (vi) Contain the provision at FAR 52.223-4, Recovered Materials 
Certification.
    (2) You may modify the clause to define the specific area of audit 
(e.g., the

[[Page 176]]

use or disposition of Government-furnished property). Legal Counsel and 
the Assistant Inspector General--Auditing or Regional Inspector 
General--Auditing, as appropriate, must concur in any modifications to 
the clause.



Sec. 514.202  General rules for solicitation of bids.



Sec. 514.202-4  Bid samples.

    (a) Solicitation requirements. (1) When you require bid samples, 
require bidders to submit samples produced by the manufacturer whose 
products will be supplied under the contract.
    (2) The FAR limits use of bid samples to cases where you cannot 
describe some characteristics of a product adequately in the 
specification or purchase description. This usually applies to 
subjective characteristics. You may determine that you need to examine 
objective characteristics of bid samples to determine the responsiveness 
of a bid. Base your determination on past experience or other valid 
considerations. In the solicitation, separately list ``Subjective 
Characteristics'' and ``Objective Characteristics.''
    (3) A sample provision appears at 552.214-72, Bid Sample 
Requirements. You may use this provision as shown or modify it to fit 
the circumstances of a procurement.
    (b) Handling and disposition of samples. (1) Retain samples from 
accepted bids for the period of contract performance. If you have no 
outstanding claims regarding the contract, dispose of the samples at the 
end of the contract term following the bidder's instructions.
    (2) If you anticipate a claim regarding the contract, retain the bid 
samples until the claim is resolved.
    (3) Retain samples from unsuccessful bids until you make award. 
After award, dispose of these samples following the bidder's 
instructions.
    (c) Using bid samples. Include the information required by FAR 
14.202-4(e) in the solicitation. Provide the number, size, and full 
description of samples with instructions on how to submit bids. List the 
characteristics that you will examine. The list needs to include any 
aspect of the bid sample the acquisition team will examine to determine 
the product(s) acceptability.



Sec. 514.203  Methods of soliciting bids.



Sec. 514.203-1  Transmittal to prospective bidders.

    Prospective bidders, as used in FAR 14.203-1, include both the 
following:
    (a) The incumbent contractor, except when its written response to 
the notice of contract action under FAR subpart 5.2 states a negative 
interest.
    (b) Bidders that responded to recent solicitations for the same or 
similar items.



Sec. 514.270  Aggregate awards.



Sec. 514.270-1  Definition.

    Aggregate award means an arrangement whereby two or more separately-
priced line items are combined for award to that bidder whose bid will 
result in the lowest overall cost to the Government for the line items 
as a group. The individual price for each item does not have to be the 
lowest bid received. (See also the definition of a ``line item'' in FAR 
3.302.)



Sec. 514.270-2  Guidelines for use.

    (a) GSA usually solicits prices and reserves the right to make award 
for individual line items. In some cases it serves GSA's best interest 
to combine two or more line items for an aggregate award. Such cases 
include when:
    (1) Users desire uniformity of design, style, and finish (e.g., 
suites of household furniture).
    (2) The articles will be assembled and used as a unit, and different 
manufacturers' components may not be interchangeable.
    (3) Users have high demand for certain articles, but demand for 
related articles is insufficient to attract competitive bids (e.g., 
various sized of socket wrenches). Awarding the low-demand articles in 
conjunction with the high-demand articles may encourage competition.
    (4) One location (delivery point) has a large requirement, and 
another location has a requirement too small to individually attract 
competitive bids.

[[Page 177]]

    (5) Awarding and administering numerous small contracts for similar 
articles or services is impractical.
    (b) Before deciding to combine items for aggregate award, consider 
the following factors:
    (1) The capability of bidders to furnish the types and quantities of 
supplies or services in the aggregate.
    (2) How grouping delivery points will affect bidders.
    (3) Which combinations will accurately project the lowest overall 
cost to the Government.
    (c) Do not use an aggregate award if it will significantly restrict 
the number of eligible bidders.



Sec. 514.270-3  Evaluation factors for award.

    Clearly state in the solicitation the basis for evaluating bids for 
aggregate award. Require bidders to submit a price on each item within 
the group or a percentage to be added or subtracted from a list price. 
Advise bidders that failure to submit prices as required within a group 
makes a bid ineligible for award for that group.



Sec. 514.270-4  Grouping line items for aggregate award.

    (a) Type of contract. While this section addresses supply contracts 
(articles and delivery points), the same principles apply to service 
contracts (types of services and service areas).
    (b) Effect on compeition. Provide for full and open competition when 
you group items for award. Grouping items for award may preclude a 
significant of firms from bidding. This occurs if firms are unable to 
provide all the types or quanities of supplies or services, or make 
deliveries to the various delivery points included in the prospective 
aggregate group.
    (c) Grouping different articles. Include only related articles in an 
aggregate group. Related articles are those normally manufactured or 
produced by a majority of prospective bidders. Grouping unrelated 
articles often restricts competition unnecessarily.
    (d) Grouping geographic locations or delivery points. Consider the 
following guidelines before deciding to group different geographic 
locations or delivery points:
    (1) A delivery point may have sufficient requirements so that 
individual shipments involve economic production runs and carload or 
truckload quanities. In this case, list it as a separate line item.
    (2) The types of bidders (i.e., small or large firms, manufacturers 
or distributors, etc.) who respond to previous solicitations can provide 
important information. For example, if previous bidders are distributors 
with franchises in certain territories, grouping different territories 
could tend to restrict competition.
    (3) Transportation costs can affect competition and pricing. They 
may constitute a significant portion of the total delivered cost. Obtain 
the advice and assistance of transportation specialists before grouping 
geographic locations or delivery points. Depending upon the supplies 
being acquired:
    (i) Grouping widespread geographic locations or delivery points may 
reduce competition or result in higher prices. It can cause you to lose 
``area pricing'' advantages provided by a supplier with a single 
production point.
    (ii) Conversely, for many small commercial items (hand tools, locks, 
etc.), manufacturers may quote the same price for delivery anywhere in 
the U.S..
    (iii) Tariff boundaries can also affect how manufacturers price 
deliveries to different areas.



Sec. 514.270-5  Evaluation methodologies for aggregate awards.

    (a) Definite quantity contracts without options. For definite 
quantity contracts without options, the evaluated bid price is the total 
bid price, as adjusted for any price-related factors identified in the 
solicitation. This reflects the actual cost to the Government and will 
identify the most advantageous bid.
    (b) Indefinite quantity contracts, requirements contracts, and 
options. Indefinite quantity and requirements contracts use estimated 
quantities. Options involve the probability of whether and when the 
options will be exercised. These situations may result in unbalanced 
bids (see FAR 15.404-1(g)), leading to inaccurate evaluation of the 
projected cost and award to other than the most advantageous bid. To 
avoid

[[Page 178]]

unbalanced bids, GSA has two preferred methods for evaluating bids for 
aggregate awards: weight factors and price list.
    (1) Weight factors method. Assign a weight to each item in a group. 
The weight is based on the portion of quantities that item represents. 
To evaluate bids, multiply each unit price by its weight factor, then 
total the results.
    (2) Price list method. Establish prices for bidders to use as a base 
for preparing their bids. Prepare a list that identifies a base price 
for each item in a group. Bidders bid a percentage factor to add to or 
subtract from the base price.



Sec. 514.270-6  Guidelines for using the weight factors method.

    (a) Use the weight factors method when you have reliable estimates 
for the quantities needed in an acquisition. Reliable estimates of 
quantities form the foundation for:
    (1) Accurate evaluation of the projected cost of each bid.
    (2) An appropriate determination of which bid is most advantageous 
to the Government for the aggregate group.
    (b) Assign a weight factor to each item in a group. Develop the 
weight factor by calculating the portion of the total quantity in a 
defined group that each item represents.
    (c) To evaluate bid prices, first multiply the price bid for each 
item (unit price X quantity) by its weight factor. Then, add the 
subtotals together to project the cost for the aggregate group.
    (d) You may reduce estimated quantities to smaller numbers by a 
common denominator. This may help facilitate the computations involved 
in evaluating bids.
    (e) Consider all price-related factors you identified in the 
solicitation. Award to the responsive and responsible bidder with the 
lowest evaluated overall cost to the Government for the aggregate group. 
This represents the most advantageous bid.



Sec. 514.270-7  Guidelines for using the price list method.

    (a) General. The price list method helps avoid unbalanced bidding 
when you need to make aggregate awards, but lack accurate estimates of 
anticipated quantities. This method establishes base prices for bidders 
to use in preparing their bids.
    (b) Solicitation requirements. When you use the price list methods, 
in the solicitation:
    (1) Include the price list.
    (2) Include an estimate of requirements.
    (3) Require the bidder to express its price as ``net'' or as a 
percentage added to or subtracted from the list prices for each group. 
Require the bidder to quote only one percentage factor for each group. 
This means that the bidder provides one percentage factor that applies 
to every item in a group; not a separate percentage for each item. 
``Net'' indicates the bidder chooses to submit the list prices as its 
bid.
    (4) Identify the percentage factor in paragraph (b)(3) of this 
section as a price related evaluation factor.
    (c) Developing list prices. You may develop price lists using one or 
more of the following sources:
    (1) Industry published prices.
    (2) Industry surveys.
    (3) Government cost estimates based on knowledge of the supplies or 
services and previous contract prices.
    (d) First time use for an item or service. The first time you use 
list prices for an item or service, give prospective bidders an 
opportunity to review the proposed list. Also provide information on how 
GSA will use the list prices. You may provide this information in a 
draft solicitation.
    (e) Balanced prices. Ensure that the list prices for the grouped 
items bear a reasonable and balanced relationship to one another. You 
may use prices from previous awards made using the weight factors method 
to develop price lists. Review those prices first to ensure they did not 
result from unbalanced bidding.
    (f) Evaluation and award. Consider all price-related factors 
identified in the solicitation. Award to the responsive and responsible 
bidder whose percentage factor produces the most favorable price to the 
Government. This represents the most advantageous bid.
    (g) Example. The following illustrates a bidding schedule 
arrangement for a

[[Page 179]]

group of items for aggregate award under the price list method:

 Drills, Twist, High Speed, Under Federal Specification (No. and Date), and Amendment (No. and Date), Amendment
                      (No. and Date) Wire Gauge Sizes, Straight Shank, Short Length, Type C
----------------------------------------------------------------------------------------------------------------
     Item No.        National Stock No.       Drill size       Est. quantity         Unit           List price
----------------------------------------------------------------------------------------------------------------
                                           Group 1 (Items 1 through 5)
----------------------------------------------------------------------------------------------------------------
1.................      5133-00-189-9246  1.................           2,800  Pkg...............          $11.16
2.................      5133-00-189-9247  2.................           2,400  Pkg...............           11.16
3.................      5133-00-189-9248  3.................           2,800  Pkg...............           10.44
4.................      5133-00-189-9249  4.................           1,600  Pkg...............           10.80
5.................      5133-00-189-9250  5.................           2,000  Pkg...............           10.80
----------------------------------------------------------------------------------------------------------------

    The bid on each item above is the list price shown minus/plus __ 
percent. (Bidder, insert ``net'' or a single percentage amount in the 
blank space and cross out minus or plus, as appropriate.)
    (h) Special considerations for contracts for store stock items. Show 
estimated quantities only if estimates of demand for each item within a 
group can be derived from Government records or verified contractor 
sales reports. Use only current estimates. If you cannot estimate the 
Government's needs, the solicitation may include past orders. (See CG 
Decision, B-209037, 82-2 CPD para 323 (1982).)
    (i) Special considerations for repair and alteration contracts. In 
the solicitation:
    (1) List the estimated quantities for work to be performed during 
both normal working hours and outside of normal working hours.
    (2) State the percent of work anticipated to be performed during 
normal working hours.
    (3) List the unit prices for work to be performed during both normal 
working hours and outside of normal working hours.
    (4) Define ``normal'' in terms of hours and days of the week.
    (5) Advise bidders of the previous year's total expenditures or 
portions of that total attributable to the listed items.
    (6) If you provide quantity estimates, state that the estimates are 
for information only and do not constitute guarantees or commitments to 
order items under the contract.
    (7) Solicit two percentage factors for the line item unit prices 
listed: one for the unit prices for work performed during normal working 
hours and the second for the unit prices for work performed outside of 
normal working hours.
    (8) You may require multiple percentages when the solicitation 
further groups unit prices by trade or business category.
    (9) For the evaluated bid price, add together the following 
percentages:
    (i) The percentage of work performed during normal work hours 
multiplied by the total estimate adjusted by the bidder's percentage 
factor for that portion of the work, plus
    (ii) The percentage of work performed during other than normal 
working hours multiplied by the total estimate adjusted by the bidder's 
percentage factor for that portion of the work.
    (10) Consider other price-related factors identified in the 
solicitation. Make award to the responsible and responsive bidder 
submitting the lowest overall evaluated bid price for the aggregate 
group. This represents the most advantageous bid.

           Subpart 514.4_Opening of Bids and Award of Contract



Sec. 514.407  Mistakes in bids.



Sec. 514.407-3  Other mistakes disclosed before award.

    (a) Delegation of authority by head of the agency. Under FAR 14.407-
3(e), contracting directors (see 502.101) are authorized, without power 
of redelegation, to make:

[[Page 180]]

    (1) The determinations regarding corrections and withdrawals under 
FAR 14.407-3(a), (b), and (c).
    (2) The corollary determinations not to permit withdrawal or 
correction under FAR 14.407-3(d).
    (b) Legal review and approval. Assigned counsel must approve 
determinations by the contracting director and contracting officer 
regarding mistakes in bid.



Sec. 514.407-4  Mistakes after award.

    The contracting director and assigned counsel review and approve 
your determinations under FAR 14.407-4(b) and (c).

                   PART 515_CONTRACTING BY NEGOTIATION

   Subpart 515.2_Solicitation and Receipt of Proposals and Information

Sec.

Sec. 515.204  Contract format.

Sec. 515.204-1  Uniform contract format.

Sec. 515.205  Issuing solicitations.

Sec. 515.209  Solicitation provisions and contract clauses.

Sec. 515.209-70  Examination of records by GSA clause.

                     Subpart 515.3_Source Selection


Sec. 515.305  Proposal evaluation.

Sec. 515.305-70  Use of outside evaluators.

                     Subpart 515.4_Contract Pricing


Sec. 515.408  Solicitation provisions and contract clauses.

 Subpart 515.5_Preaward, Award, and Postaward Notifications, Protests, 
                              and Mistakes


Sec. 515.506  Postaward debriefing of offerors.

                      Subpart 515.70_Use of Samples


Sec. 515.7002  Procedures.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37214, July 9, 1999, unless otherwise noted.

   Subpart 515.2_Solicitation and Receipt of Proposals and Information



Sec. 515.204  Contract format.



Sec. 515.204-1  Uniform contract format.

    (a) The uniform contract format is not required for leases of real 
property.
    (b) Each solicitation and contract must include the two notices in 
paragraphs (b)(1) and (b)(2) of this section, except that acquisitions 
of interests in real property, must include only the notice in (b)(1):
    (1) ``The information collection requirements contained in this 
solicitation/contract are either required by regulation or approved by 
the Office of Management and Budget pursuant to the Paperwork Reduction 
Act and assigned OMB Control No. 3090-0163.''
    (2) ``GSA's hours of operation are 8:00 a.m. to 4:30 p.m. Requests 
for preaward debriefings postmarked or otherwise submitted after 4:30 
p.m. will be considered submitted the following business day. Requests 
for postaward debriefings delivered after 4:30 p.m. will be considered 
received and filed the following business day.''



Sec. 515.205  Issuing solicitations.

    Potential sources, as used in FAR 15.205, include both of the 
following:
    (a) The incumbent contractor, except when its written response to 
the notice of contract action under FAR subpart 5.2 states a negative 
interest.
    (b) Offerors that responded to recent solicitations for the same or 
similar items.



Sec. 515.209  Solicitation provisions and contract clauses.



Sec. 515.209-70  Examination of records by GSA clause.

             Clause for Other Than Multiple Award Schedules

    (a) For other than multiple award schedule (MAS) contracts, insert 
the clause at 552.215-70, Examination of Records by GSA, in 
solicitations and contracts over $100,000, including acquisitions of 
leasehold interests in real property, that meet any of the following 
conditions:

[[Page 181]]

    (1) Involve the use or disposition of Government-furnished property.
    (2) Provide for advance payments, progress payments based on cost, 
or guaranteed loan.
    (3) Contain a price warranty or price reduction clause.
    (4) Involve income to the Government where income is based on 
operations under the control of the contractor.
    (5) Include an economic price adjustment clause where the adjustment 
is not based solely on an established, third party index.
    (6) Are requirements, indefinite-quantity, or letter type contracts 
as defined in FAR part 6.
    (7) Are subject to adjustment based on a negotiated cost escalation 
base.
    (8) Contain the provision of FAR 52.223-4, Recovered Material 
Certification.
    (b) You may modify the clause at 552.215-70 to define the specific 
area of audit (e.g., the use or disposition of Government-furnished 
property, compliance with the price reduction clause). Counsel and the 
Assistant Inspector General--Auditing or Regional Inspector General-- 
Auditing, as appropriate, must concur in any modifications to the 
clause.

                   Clause for Multiple Award Schedules

    (c) Insert the clause at 552.215-71, Examination of Records by GSA 
(Multiple Award Schedule), in solicitations and contracts for MAS 
contracts.
    (d) With the Senior Procurement's Executive approval, you may modify 
the clause at 552.215-71 to provide for post-award access to and the 
right to examine records to verify that the pre-award/modification 
pricing, sales or other data related to the supplies or services offered 
under the contract which formed the basis for the award/modification was 
accurate, current, and complete. The following procedures apply:
    (1) Such a modification of the clause must provide for the right of 
access to expire 2 years after award or modification.
    (2) Before modifying the clause, you must make a determination that 
absent such access there is a likelihood of significant harm to the 
Government and submit it to the Senior Procurement Executive for 
approval.
    (3) The determinations under paragraph (d)(2) of this section must 
be made on a schedule-by-schedule basis.

                     Subpart 515.3_Source Selection



Sec. 515.305  Proposal evaluation.

    (a) Restrictions placed on a proposal by the submitter. If you 
receive a proposal with more restrictive conditions than those in the 
provision at FAR 52.215-1(e), ask whether the submitter is willing to 
accept the conditions of the paragraph at FAR 52.215-1(e). If the 
submitter refuses, consult with legal counsel on whether to accept the 
proposal as marked or return it.
    (b) Actions before releasing proposal. Before releasing any proposal 
to an evaluator you must take all the following actions:
    (1) Obtain the signed original ``Conflict of Interest Acknowledgment 
and Nondisclosure Agreement'' from each Government and nongovernment 
individual serving as an evaluator. Use the Acknowledgment/Agreement in 
Figure 515.3-1.
    (i) For employees of other Executive agencies, replace the reference 
in paragraph (c) of the Acknowledgement/Agreement to GSA's supplemental 
standards with a reference to the applicable agency.
    (ii) for nongovernment evaluators, substitute paragraph (c) of the 
Acknowledgement/Agreement with the following language and delete 
paragraph (h):

    (c) I have read and understand the requirements of subsection 27(a) 
and 27(b) of the Office of Federal Procurement Policy Act (41 U.S.C. 
423).

    (2) Attach to each proposal a cover page bearing the following 
notice:

                Government Notice for Handling Proposals

    To anyone receiving this proposal or proposal abstract:
    (1) This proposal must be used and disclosed for evaluation purposes 
only.
    (2) You must apply a copy of this Government notice to any 
reproduction or abstract of this proposal.

[[Page 182]]

    (3) You must comply strictly with any authorized restrictive notices 
which the submitter places on this proposal.
    (4) You must not disclose this proposal outside the Government for 
evaluation purposes except to the extent authorized by, and in 
accordance with, the procedures in 48 CFR 515.305-71.



Sec. 515.305-70  Use of outside evaluators.

    (a) Conditions. To use outside evaluators, you must meet the 
restrictions in FAR 37.203 and 537.2.
    (b) Limitations on disclosing proposal information. You may disclose 
proposal information outside the Government before the Government's 
decision as to contract award only to the extent authorized in this 
section. Disclosure and handling must comply with FAR 3.1 and 503.1.
    (c) Solicitation notice. Include in the solicitation a notice 
substantially as follows:

                    Notice About Releasing Proposals

    (1) The Government intends to disclose proposals received in 
response to this solicitation to nongovernment evaluators.
    (2) Each evaluator will sign and provide to GSA a ``Conflict of 
Interest Acknowledgment and Nondisclosure Agreement.''

 Figure 515.3-1--Conflict of Interest Acknowledgment and Nondisclosure 
                                Agreement

     Conflict of Interest Acknowledgment and Nondisclosure Agreement

    For proposals submitted in response to GAS solicitation no. ____, I 
agree to the following:
    (a) To the best of my knowledge and belief, no conflict of interest 
exists that may either:
    (1) Diminish my capacity to impartially review the proposals 
submitted.
    (2) Or result in a biased opinion or unfair advantage.
    (b) In making the above statement, I have considered all the 
following factors that might place me in a position of conflict, real or 
apparent, with the evaluation proceedings:
    (1) All my stocks, bonds, other outstanding financial interests or 
commitments.
    (2) All my employment arrangements (past, present, and under 
consideration).
    (3) As far as I know, all financial interests and employment 
arrangements of my spouse, minor children, and other members of my 
immediate household.
    (c) I have read and understand the requirements of the Standards of 
Ethical Conduct for Employees of the Executive Branch (5 CFR Part 2635) 
and Supplemental Standards of Ethical Conduct for Employees of the 
General Service Administration (5 CFR Part 6701).
    (d) I have a continuing obligation to disclose any circumstances 
that may create an actual or apparent conflict of interest. If I learn 
of any such conflict, I will report it immediately to the Contracting 
Officer. I will perform no more duties related to evaluating proposals 
until I receive instructions on the matter.
    (e) I will use proposal information for evaluation purposes only. I 
understand that any authorized restriction on disclosure placed on the 
proposal by the prospective contractor, prospective subcontractor, or 
the Government applies to any reproduction or abstracted information of 
the proposal.
    (f) I will use my best efforts to safeguard proposal information 
physically. I will not disclose the contents of, nor release any 
information about, the proposals to anyone other than:
    (1) The Source Selection Evaluation Board or other panel assembled 
to evaluate proposals submitted in response to the solicitation 
identified above.
    (2) Other individuals designed by the contracting Officer.
    (g) After completing evaluation, I will return to the Government all 
copies of the proposals and any abstracts.
    (h) GSA Appropriations Act restriction: These restrictions are 
consistent with and do not supersede, conflict with or otherwise alter 
the employee obligations, rights, or liabilities created by Executive 
Order No. 12958; section 7211 of title 5, United States Code (governing 
disclosure of Congress); section 1034 of title 10, United States Code, 
as amended by the Military Whistleblower Protection Act (governing 
disclosure to Congress by members of the military); section 2302(b)(8) 
of title 5, United States Codes, as amended by the Whistleblower 
Protection Act (governing disclosures of illegality, waste, fraud, abuse 
or public health or safety threats); the Intelligence Identities 
Protection Act of 1982 (50 U.S.C. 421 et seq.) (governing disclosures 
that could expose confidential Government agents); and the statutes 
which protect against disclosure that may compromise the national 
security, including sections 641, 793, 794, 798, and 952 of title 18, 
United States Code, and section 4(b) of the Subversive Activities Act of 
1950 (50 U.S.C. 783(b). The definitions, requirements, obligations, 
rights, sanctions, and liabilities created by said Executive order and 
listed statutes are incorporated into this agreement and are 
controlling.
_______________________________________________________________________
(Enter name of evaluator and organization)

[[Page 183]]

_______________________________________________________________________
Date

                     Subpart 515.4_Contract Pricing



Sec. 515.408  Solicitation provisions and contract clauses.

      MAS Requests for Information Other Than Cost or Pricing Data

    (a) You should use Alternative IV of the FAR provision at 52.215-20, 
Requirements for Cost or Pricing Data or Information Other than Cost or 
Pricing Data, for MAS contracts to provide the format for submission of 
information other than cost or pricing data for MAS contracts. To 
provide uniformity in request under the MAS program, you should insert 
the following in paragraph (b) of the provision:
    (1) An offer prepared and submitted in accordance with the clause at 
552.212-70, Preparation of Offer (Multuiple Award Schedule).
    (2) Commercial sales practices. The Offeror shall submit information 
in the format provided in this solicitation in accordance with the 
instructions at Figure 515.4 of the GSA Acquisition Regulation (48 CFR 
515-2), or submit information in the Offeror's own format.
    (3) Any additional supporting information requested by the 
Contracting Officer. The Contracting Officer may require additional 
supporting information, but only to the extent necessary to determine 
whether the price(s) offered is fair and reasonable.
    (4) By submission of an offer in response to this solicitation, the 
Offeror grants the Contracting Officer or an authorized representative 
the right to examine, at any time before initial award, books, records, 
documents, papers, and other directly pertinent records to verify the 
pricing, sales and other data related to the supplies or services 
proposed in order to determine the reasonableness of price(s). Access 
does not extend to Offeror's cost or profit information of other data 
relevant solely to the Offeror's determination of the prices to be 
offered in the catalog or marketplace.
    (b) Insert the following format for commercial sales practices in 
the exhibits or attachments section of the solicitation and resulting 
contract (see FAR 12.303).

                    Commercial Sales Practices Format

Name of Offeror _____ SIN(s) ___
    Note: Please refer to Clause 552.212-70, Preparation of Offer 
(Multiple Award Schedule), for additional information concerning your 
offer. Provide the following information for each SIN (or group of SINs 
or SubSIN for which information is the same).

    (1) Provide the dollar value of sales to the general public at or 
based on an established catalog or market price during the previous 12-
month period or the offerors last fiscal year: $____. State beginning 
and ending of the 12 month period. Beginning ____ ending ____. In the 
event that a dollar value is not an appropriate measure of the sales, 
provide and describe your own measure of the sales of the item(s).
    (2) Show your total projected annual sales to the Government under 
this contract for the contract term, excluding options, for each SIN 
offered. If you currently hold a Federal Supply Schedule contract for 
the SIN the total projected annual sales should be based on your 
mostrecent 12 months of sales under that contract.

SIN ______  $______
SIN ______  $______
SIN ______  $______

    (3) Based on your written discounting policies (standard commercial 
sales practices in the event you do not have written discounting 
policies), are the discounts and any concessions which you offer the 
Government equal to or better than your best price (discount and 
concessions in any combination) offered to any customer acquiring the 
same items regardless of quantity or terms and conditions? YES__ NO__ 
(See definition of ``concession'' and ``discount'' in 552.212-70.)
    (4)(a) Based on your written discounting policies (standard 
commercial sales practices in the event you do not have written 
discounting policies), provide information as requested for each SIN (or 
group of SINs for which the information is the same) in accordance with 
the instructions at Figure 515.4, which is provided in this solicitation 
for your convenience. The information should be provided in the chart 
below or in an equivalent format developed by the offeror. Rows should 
be added to accommodate as many customers as required.

----------------------------------------------------------------------------------------------------------------
                                                      Column 3  Quantity/                          Column 5
       Column 1  Customer         Column 2  Discount        Volume        Column 4  FOB Term      Concessions
----------------------------------------------------------------------------------------------------------------
 
 
 
----------------------------------------------------------------------------------------------------------------

    (b) Do any deviations from your written policies or standard 
commercial sales practices disclosed in the above chart ever result

[[Page 184]]

in better discounts (lower prices) or concessions than indicated? YES_ 
NO_. If YES, explain deviations in accordance with the instructions at 
Figure 515.4, which is provided in this solicitation for your 
convenience.
    (5) If you are a dealer/reseller without significant sales to the 
general public, you should provide manufacturers' information required 
by paragraphs (1) through (4) above for each item/SINoffered, if the 
manufacturer's sales under any resulting contract are expected to exceed 
$500,000. You must also obtain written authorization from the 
manufacturer(s) for Government access, at any time before award or 
before agreeing to a modification, to the manufacturer's sales records 
for the purpose of verifying the information submitted by the 
manufacturer. The information is required in order to enable the 
Government to make a determination that the offered price is fair and 
reasonable. To expedite the review and processing of offers, you should 
advise the manufacturer(s) of this requirement. The contracting officer 
may require the information be submitted on electronic media with 
commercially available spreadsheet(s). The information may be provided 
by the manufacturer directly to the Government. If the manufacturer's 
item(s) is being offered by multiple dealers/resellers, only one copy of 
the requested information should be submitted to the Government. In 
addition, you must submit the following information along with a listing 
of contact information regarding each of the manufacturers whose 
products and/or services are included in the offer (include the 
manufacturer's name, address, the manufacturer's contact point, 
telephone number, and FAX number) for each model offered by SIN:
    (a) Manufacturer's Name.
    (b) Manufacturer's Part Number.
    (c) Dealer's/Reseller's Part Number.
    (d) Product Description.
    (e) Manufacturer's List Price.
    (f) Dealer's/Reseller's percentage discount from list price or net 
prices.

                             (End of Format)

    (c) Include the instructions for completing the commercial sales 
practices format in Figure 515.4 in solicitations issued under the MAS 
program.

    Figure 515.4--Instructions for Commercial Sales Practices Format

    If you responded ``yes'' to question (3), on the Commercial Sales 
Practices Format in paragraph (b) of this section, complete the chart in 
question (4)(a) for the customer(s) who receive your best discount. If 
you responded ``no'', complete the chart in question (4)(a) showing your 
written policies or standard sales practices for all customers or 
customer categories to whom you sell at a price (discounts and 
concessions in combination) that is equal to or better than the price(s) 
offered to the Government under this solicitation or with which the 
Offeror has a current agreement to sell at a discount which equals or 
exceeds the discount(s) offered under this solicitation. Such agreement 
shall be in effect on the date the offer is submitted or contain an 
effective date during the proposed multiple award schedule contract 
period. If your offer is lower than your price to other customers or 
customers categories, you will be aligned with the customer or category 
of customer that receives your best price for purposes of the Price 
Reductions clause at 552.238-75. The Government expects you to provide 
information required by the format in accordance with these instructions 
that is, to the best of your knowledge and belief, current, accurate, 
and complete as of 14 calender days prior to its submission. You must 
also disclose any changes in your price list(s), discounts and/or 
discounting policies which occur after the offer is submitted, but 
before the close of negotiations. If your discount practices vary by 
model or product line, the discount information should be by model or 
product line as appropriate. You may limit the number of models or 
product lines reported to those which exceed 75% of actual historical 
Government sales (commercial sales may be substituted if Government 
sales are unavailable) value of the special item number (SIN).

   Column 1--Identify the Applicable Customer or Category of Customer

    A ``customer'' is any entity, except the Federal Government, which 
acquires supplies or services from the Offeror. The term customer 
includes, but is not limited to original equipment manufacturers, value 
added resellers, state and local Governments, distributors, educational 
institutions (an elementary, junior high, or degree granting school 
which maintains a regular faculty and established curriculum and an 
organized body of students), dealers, national accounts, and end users. 
In any instance where the Offeror is asked to disclose information for a 
customer, the Offeror may disclose information by category of customer 
if the Offeror's discount policies or practices are the same for all 
customers in the category. (Use a separate line for each customer or 
category of customer.)

                     Column 2--Identify the Discount

    The term ``discount'' is as defined in solicitation clause 552.212-
70, Preparation of Offer (Multiple Award Schedule). Indicate the best 
discount (based on your written discounting policies or standard 
commercial discounting practices if you do not have written discounting 
policies) at which you sell to the customer or category of customer 
identified

[[Page 185]]

in column 1, without regard to quantity; terms and conditions of the 
agreements under which the discounts are given; and whether the 
agreements are written or oral. Net prices or discounts off of other 
price lists should be expressed as percentage discounts from the price 
list which is the basis of your offer. If the discount disclosed is a 
combination of various discounts (prompt payment, quantity, etc.), the 
percentage should be broken out for each type of discount. If the price 
lists which are the basis of the discounts given to the customers 
identified in the chart are different than the price list submitted upon 
which your offer is based, identify the type or title and date of each 
price list. The contracting officer may require submission of these 
price lists. To expedite evaluation, offerors may provide these price 
lists at the time of submission.

           Column 3--Identify the Quantity or Volume of Sales

    Insert the minimum quantity or sales volume which the identified 
customer or category of customer must either purchase/order, per order 
or within a specified period, to earn a discount indicate the time 
period.

  Column 4--Indicate the FOB Delivery Term for Each Identified Customer

    See FAR 47.3 for an explanation of FOB delivery terms.

  Column 5--Indicate Concessions Regardless of Quantity Granted to the 
               Identified Customer or Category of Customer

    Concessions are defined in solicitation clause 552.12-70, 
Preparation of Offers (Multiple Award Schedule). If the space provided 
is inadequate, the disclosure should be made on a separate sheet by 
reference.
    If you respond ``yes'' to question 4(b) in the Commercial Sales 
Practices Format, provide an explanation of the circumstances under 
which you deviate from your written policies or standard commercial 
sales practices disclosed in the chart on the Commercial Sales Practices 
Format and explain how often they occur. Your explanation should include 
a discussion of situations that lead to deviations from standard 
practice, an explanation of how often they occur, and the controls you 
employ to assure the integrity of your pricing. Examples of typical 
deviations may include, but are not limited to, one time goodwill 
discounts to charity organizations or to compensate an otherwise 
disgruntled customer; a limited sale of obsolete or damaged goods; the 
sale of sample goods to a new customer, or the sales of prototype goods 
for testing purposes.
    If deviations from your written policies or standard commercial 
sales practices disclosed in the chart on the Commercial Sales Practices 
Format are so significant and/or frequent that the Contracting Officer 
cannot establish whether the price(s) offered is fair and reasonable, 
then you may be asked to provide additional information. The Contracting 
Officer may ask for information to demonstrate that you have made 
substantial sales of the item(s) in the commercial market consistent 
with the information reflected on the chart on the Commercial Sales 
Practices Format, a description of the conditions surrounding those 
sales deviations, or other information that may be necessary in order 
for the Contracting Officer to determine whether your offered price(s) 
is fair and reasonable. In cases where additional information is 
requested the Contracting Officer will target the request in order to 
limit the submission of data to that needed to establish the 
reasonableness of the offered price.

                             (End of figure)

    (d) Insert the clause at 552.215-72, Price Adjustment--Failure to 
Provide Accurate Information, in solicitations and contracts under the 
MAS program.
    (e) You should use Alternate IV of FAR 52.215-21, Requirements for 
Cost or Pricing Data or Information Other Than Cost or Pricing Data--
Modifications, to provide for submission of information other than cost 
or pricing data for MAS contracts. To provide for uniformity in requests 
under the MAS program, you should insert the following in paragraph (b) 
of the clause:
    (1) Information required by the clause at 552.243-72, Modifications 
(Multiple Award Schedule).
    (2) Any additional supporting information requested by the 
Contracting Officer. The Contracting Officer may require additional 
supporting information, but only to the extent necessary to determine 
whether the price(s) offered is fair and reasonable.
    (3) By submitting a request for modification, the Contractor grants 
the Contracting Officer or an authorized representative the right to 
examine, at any time before agreeing to a modification, books, record, 
documents, papers, and other directly pertinent records to verify the 
pricing, sales and other data related to the supplies or services 
proposed in order to determine the reasonableness of price(s). Access 
does not extent to Contractor's cost or profit information or other data 
related solely to the Contractor's determination of the prices to be 
offered in the catalog or marketplace.

[64 FR 37214, July 9, 1999, as amended at 65 FR 11247, Mar. 2, 2000]

[[Page 186]]

 Subpart 515.5_Preaward, Award, and Postaward Notifications, Protests, 
                              and Mistakes



Sec. 515.506  Postaward debriefing of offerors.

    For purposes of determining the date of receipt of a request for a 
post award debriefing, GSA's hours of operation are 8:00 a.m. to 4:30 
p.m. Request received after 4:30 p.m. will be considered received the 
following business day.

                      Subpart 515.70_Use of Samples



Sec. 515.7002  Procedures.

    (a) Unsolicited samples. The reference to FAR 14.404-2(d) in FAR 
14.202-4(g) does not apply.

    However, qualifications in the proposal that are at variance with 
the Government's requirements, constitute deficiencies. Resolve these as 
provided in FAR 15.306.

    (b) Solicitation requirements.
    (1) Use the clause at FR 52.214-20. The second sentence in paragraph 
(c) of the clause does not apply. Substitute a sentence substantially as 
follows:

    Failure of the bid samples to conform to all the required 
characteristics listed in the solicitation constitutes a deficiency in 
the proposal (see FAR 15.306).

    (2) In addition to listing subjective characteristics that you 
cannot adequately describe in the specification, you may list and 
evaluate objective characteristics. To include objective 
characteristics, you must determine that examination of such 
characteristics is essential to the acquisition of any acceptable 
product. Base your determination on past experience or other valid 
considerations.
    (c) FAR 52.215-1(c)(3) applies to samples received after the time 
set for receipt of offers.

                       PART 516_TYPES OF CONTRACTS

                   Subpart 516.2_Fixed Price Contracts

Sec.

Sec. 516.203-4  Contract clauses.

               Subpart 516.5_Indefinite-Delivery Contracts


Sec. 516.506  Solicitation provisions and contract clauses.

   Subpart 516.6_Time-and-Materials, Labor-Hour, and Letter Contracts


Sec. 516.603  Letter contracts.

Sec. 516.603-3  Limitations.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37218, July 9, 1999, unless otherwise noted.

                   Subpart 516.2_Fixed Price Contracts



Sec. 516.203-4  Contract clauses.

    (a) Multiple award schedules. Do not use FAR 52.216-2, 52.216-3, or 
52.216-4 in negotiated acquisitions based on discounts from established 
commercial catalogs or pricelists. Instead, use:
    (1) 552.216-70, Economic Price Adjustment--FSS Multiple Award 
Schedule Contracts, in a 1-year solicitation or contract.
    (2) 552.216-70 (Alternate I) in multiyear solicitations and 
contracts.
    (b) Stock or Special Order Program Contracts. In multiyear 
solicitations and contracts, after making the determination required by 
FAR 16.203-2, use 552.216-71, Economic Price Adjustment-Stock and 
Special Order Program Contract, or a clause prepared as authorized in 
paragraph (a)(2)(ii) of this subsection.
    (1) If the contract includes one or more options to extend the term 
of the contract, use the clause with its Alternate I or a clause 
substantially the same as 552.216-71 with its Alternate I suitably 
modified.
    (2) In a contract requiring a minimum adjustment before the price 
adjustment mechanism is effectuated, use the basic clause with Alternate 
II or with Alternate I and Alternative II.
    (3) If the Producer Price Index is not an appropriate indicator for 
price adjustment, modify the clause to use an alternate indicator for 
adjusting prices. Similarly, if other aspects of 552.216-71 are not 
appropriate, use an alternate clause following established procedures.
    (c) Adjustments based on cost indexes of labor or material. (1) If 
you decide to

[[Page 187]]

provide for adjustments based on cost indexes of labor or material, 
prepare a clause that defines each of the following elements:
    (i) The type of labor and/or material subject to adjustment.
    (ii) The labor rates, including any fringe benefits and/or unit 
prices of materials that may be increased or decreased.
    (iii) The index(es) that will be used to measure changes in price 
levels and the base period or reference point from which changes will be 
measured.
    (iv) The period during which the price(s) will be subject to 
adjustment.
    (2) The contracting director must approve use of this clause.

               Subpart 516.5_Indefinite-Delivery Contracts



Sec. 516.506  Solicitation provisions and contract clauses.

    (a) In solicitations and contracts for stock or special order 
program items, when the contract authorizes FSS and other activities to 
issue delivery or task orders, insert the clause at 552.216-72, 
Placement of Orders. If only FSS will issue delivery or task orders, 
insert the clause with its Alternate I.
    (b) In solicitations and contracts for single or multiple award 
schedule program items, insert the clause at 552.216-72, Placement of 
Orders, with its Alternate II.
    (c) If the clause at 552.216-72 is prescribed, insert the provision 
at 552.216-73, Ordering Information, in solicitations for stock items 
and in other FSS solicitations. Use 552.216-73 Alternate I when 552.216-
72 Alternate I is prescribed. Use 552.216-73 Alternate II when 552.72 
Alternate II is prescribed.

   Subpart 516.6_Time-and-Materials, Labor-Hour, and Letter Contracts



Sec. 516.603  Letter contracts.



Sec. 516.603-3  Limitations.

                    Architect-Engineer (A-E) Services

    (a) Requirement for a price proposal. Before you award a letter 
contract, the proposed A-E must provide a price proposal for the non-
design effort.
    (b) Contents of each letter contract. You must include the following 
information in the letter contract:
    (1) The scope. If you include the design effort, only authorize the 
A-E to perform those services that are independent of the design effort 
(for example, feasibility studies, existing facility surveys or site 
investigation, etc.). Do not authorize the A-E to begin the design 
effort before the letter contract is definitized.
    (2) A definitization schedule. Include dates for each of the 
following:
    (i) Submission of the design fee proposal.
    (ii) Start of negotiations.
    (iii) Definitization. This date must be no later than 90 days after 
the date of the letter contract.
    (3) A limitation on the Government's liability for the non-design 
effort to be performed under the contract. Insert this amount in FAR 
52.216-24, Limitation of Government Liability.
    (c) Unilateral price decision. If you must issue a unilateral price 
decision, the maximum contract amount must not exceed a reasonable price 
for the excludable items plus the 6 percent statutory fee limitation for 
the project.

[[Page 188]]

                  PART 517_SPECIAL CONTRACTING METHODS

                   Subpart 517.1_Multiyear Contracting

Sec.

Sec. 517.109  Contract clauses.

                          Subpart 517.2_Options


Sec. 17.200  Scope of subpart.

Sec. 17.202  Use of options.

Sec. 17.203  Solicitations.

Sec. 17.207  Exercise of options.

Sec. 17.208  Solicitation provisions and contract clauses.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37218, July 9, 1999, unless otherwise noted.

                   Subpart 517.1_Multiyear Contracting



Sec. 517.109  Contract clauses.

    Use of FAR 52.217-2, Cancellation Under Multi-year Contracts, is 
optional in multiyear contracts authorized by 40 U.S.C. 490(a)(14) for 
maintenance and repair of fixed equipment in federally-owned buildings 
and services and 40 U.S.C. 481(a)(3) for public utility services.

                          Subpart 517.2_Options



Sec. 517.200  Scope of subpart.

    (a) This subpart applies to all GSA contracts for supplies and 
services, including:
    (1) Services involving construction, alteration, or repair 
(including dredging, excavating, and painting) of buildings, bridges, 
roads, or other kinds of real property.
    (2) Architect-engineer services.
    (b) If a requirement in this subpart is inconsistent with FAR 17.2, 
this subpart takes precedence.



Sec. 517.202  Use of options.

    (a) Supplies or services.
    (1) You should use options when they meet one or more of the 
following objectives:
    (i) Reduce procurement lead time and associated costs.
    (ii) Ensure continuity of contract support.
    (iii) Improve overall contractor performance.
    (iv) Facilitate longer term contractual relationships with those 
contractors that continually meet or exceed quality performance 
expectations.
    (2) An option is normally in the Government's interest in the 
following circumstances:
    (i) You anticipate a need for additional supplies or services during 
the contract term.
    (ii) Multiyear contracting authority is not available or its use is 
inappropriate and you anticipate a need for additional supplies or 
services beyond the initial contract term.
    (iii) There is a need for continuity of supply or service support.
    (iv) Funds are not available for the entirety of the Government's 
needs, but are likely to become available during the contract term.
    (v) The initial contract will be used to evaluate the performance of 
an emerging small business.
    (3) Do not use an option if the market price is likely to change 
substantially and an economic price adjustment clause inadequately 
protects the Government's interest.
    (b) Construction. For limitations on the use of options, see 536.213 
and 536.270.



Sec. 517.203  Solicitations.

    A solicitation that includes an option to extend should inform 
offerors that the contract could result in a long term contractual 
relationship subject to both of the following conditions:
    (a) Continuing need by GSA.
    (b) Level of contract performance that at least meets GSA's quality 
performance expectations.



Sec. 517.207  Exercise of options.

    Before exercising an option, you must:
    (a) Synopsize it unless you meet of the following conditions:
    (1) The option was evaluated as part of the original competition.
    (2) The contract action meets an exception in FAR 5.202.
    (b) Conclude that the contractor's performance under the contract 
met or exceeded the Government's expectation

[[Page 189]]

for quality performance, unless another circumstance justifies an 
extended contractual relationship.
    (c) Determine that the option price is fair and reasonable.



Sec. 517.208  Solicitation provisions and contract clauses.

    (a) For solicitations under FSS's Stock or Special Order Program, 
insert a provision substantially the same as the provision at 552.217-
70, Evaluation of Options, if both of the following conditions apply:
    (1) The solicitation contains an option to extend the term of the 
contract.
    (2) The contract will be fixed price and contain an economic price 
adjustment clause.
    (b) Insert the provision at 552.217-71, Notice Regarding Option(s), 
or a similar provision, in solicitations that include an option for 
increased quantities of supplies or services or an option to extend.

[[Page 190]]



                   SUBCHAPTER D_SOCIOECONOMIC PROGRAMS

                    PART 519_SMALL BUSINESS PROGRAMS

               Subpart 519.5_Set-Asides for Small Business

Sec.

Sec. 519.508  Soliciation provisions for contract clauses.

         Subpart 519.7_The Small Business Subcontracting Program


Sec. 519.708  Contract clauses.

Sec. 519.708-70  Solicitation provisions.

 Subpart 519.8_Contracting With the Small Business Administration (The 
                              8(a) Program)


Sec. 519.870  Direct 8(a) contracting.

Sec. 519.870-8  Contract clauses.

    Subpart 519.12_Small Disadvantaged Business Participation Program


Sec. 519.1202  Evaluation factor or subfactor.

Sec. 519.1202-2  Applicability.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37219, July 9, 1999, unless otherwise noted.

               Subpart 519.5_Set-Asides for Small Business



Sec. 519.508  Solicitation provisions for contract clauses.

    Insert 552.219-70, Allocation of Orders--Partially Set-Asides Items, 
in solicitations and requirements type supply contracts that are 
partially set aside for small business.

         Subpart 519.7_The Small Business Subcontracting Program



Sec. 519.708  Contract clauses.



Sec. 519.708-70  Solicitation provisions.

    Insert the following provisions as directed:
    (a) 552.219-71, Notice to Offerors of Subcontracting Plan 
Requirements, on the cover page of solicitations containing the clause 
at FAR 52.219-9, Small Business Subcontracting Plan.
    (b) 552.219-72, Preparation, Submission, and Negotiations of 
Subcontracting Plans, in solicitations requiring submission of the 
subcontracting plan with initial offers.
    (c) 552.219-73, Goals for Subcontracting Plan as follows:
    (1) Use the basic provision in sealed bid solicitations containing 
FAR 52.219-9 if you are able to establish realistic target goals.
    (2) Use Alternate I in:
    (i) sealed bid solicitations if you cannot establish target goals.
    (ii) Negotiated solicitations that include FAR 52.219-9, but do not 
include 552.219-72.

 Subpart 519.8_Contracting With the Small Business Administration (The 
                              8(a) Program)



Sec. 519.870  Direct 8(a) contracting.



Sec. 519.870-8  Contract clauses.

    (a) Insert the following clauses in solicitations, contracts, and 
orders issued under the MOU:
    (1) Insert the clause at 552.219-74, Section 8(a) Direct Award.
    (2) Insert the clause at FAR 52.219-14, Limitation on 
Subcontracting.
    (3) Insert the clause at FAR 52.219-18, Notification of Competition 
Limited to Eligible 8(a) Concerns, Substitute the following paragraph 
for paragraph (c) of the clause. Add the word ``Deviation'' at the end 
of the clause title.

    (c) Any award resulting from this solicitation will be made directly 
by the Contracting Officer to the successful 8(a) offeror selected 
through the evaluation criteria set forth in this solicitation.

    (b) Do not use the clauses at FAR 52.219-11, Special 8(a) Contract 
Conditions, FAR 52.219-12, Special 8(a) Subcontract Conditions, or FAR 
52.219-17, Section 8(a) Award.

[[Page 191]]

    Subpart 519.12_Small Disadvantaged Business Participation Program



Sec. 519.1202  Evaluation factor or subfactor.



Sec. 519.1202-2  Applicability.

    In addition to the exception in FAR 19.1202-2, do not evaluate the 
extent of participation of SDB concerns in performance of multiple award 
schedule contracts when all fair and reasonable offers from responsible 
sources are accepted.

      PART 522_APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITIONS

Sec.

Sec. 522.001  Defintion.

                   Subpart 522.1_Basic Labor Policies


Sec. 522.101  Labor relations.

Sec. 522.101-1  General.

Sec. 522.103-5  Contract clauses.

   Subpart 522.4_Labor Standards for Contracts Involving Construction


Sec. 522.406  Administration and enforcement.

Sec. 522.406-6  Payrolls and statements.

               Subpart 522.8_Equal Employment Opportunity


Sec. 522.803  Responsibilities.

Sec. 522.804  Affirmative action programs.

Sec. 522.804-1  Nonconstruction.

Sec. 522.805  Procedures.

Sec. 522.807  Exemptions.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37220, July 9, 1999, unless otherwise noted.



Sec. 522.001  Definition.

    Agency labor advisory, as used in this part, means the Director of 
the GSA Acquisition Policy Division, Office of Acquisition Policy.

                   Subpart 522.1_Basic Labor Policies



Sec. 522.101  Labor relations.



Sec. 522.101-1  General.

    (a) GSA personnel performing official duties must maintain GSA's 
impartiality in disputes between labor and contractor management by 
refraining from involvement in or expressing a position on:
    (1) Labor negotiations between contractors and unions.
    (2) The merits of any dispute between labor and a contractor's 
management.
    (b) The Office of General Counsel (OGC) and the agency labor 
advisor:
    (1) Serve as focal points on contractor labor relations.
    (2) Initiate contact on contractor labor relations matters with 
national offices of labor organizations, Government departments, 
agencies or other governmental organizations.
    (3) Serve as a clearinghouse for information on labor laws 
applicable to Government acquisitions.
    (4) Respond to questions involving FAR Part 22, this part, or other 
contractor labor relations matters concerning GSA acquisition programs. 
OGC determines the agency's legal position.



Sec. 522.103-5  Contract clauses.

    Insert FAR 52.222-1, Notice to the Government of Labor Disputes, in 
solicitations and contracts for items on the DoD Master Urgency List.

   Subpart 522.4_Labor Standards for Contracts Involving Construction



Sec. 522.406  Administration and enforcement.



Sec. 522.406-6  Payrolls and statements.

   Statement From Prime Contractors or Subcontractors That Personally 
                              Perform Work

    (a) Weekly payrolls and statements of compliance with respect to 
payment of wages are not required from a prime contractor or a 
subcontractor that personally performs work.
    (b) Instead, a prime contractor or a subcontractor that personally 
performs work must submit weekly certified statements clearly showing 
the following information:
    (1) The individual's contractual relationship.
    (2) The scope and date(s) the individual performed the work.
    (3) The individual received no wages for the labor performed.

[[Page 192]]

    (4) No mechanics or laborers were employed in the prosecution of the 
work.
    (c) Use GSA Form 618-D, Statement to be Submitted When Work is 
Performed Personally, to furnish this information.

               Subpart 522.8_Equal Employment Opportunity



Sec. 522.803  Responsibilities.

    Submit questions on the applicability of E.O. 11246 and implementing 
regulations to assigned legal counsel.



Sec. 522.804  Affirmative action programs.



Sec. 522.804-1  Nonconstruction.

    (a) The requirements of FAR 22.804 also apply to each contractor and 
subcontractor with 50 or more employees who either:
    (1) Serves as a depository of Government funds.
    (2) Is a financial institution serving as an issuing and paying 
agent for U.S. savings bonds and savings notes.
    (b) Contractors, subcontractors, and financial institutions must 
develop a written affirmative action compliance program for each of its 
establishments even if the amount held is less than $50,000.



Sec. 522.805  Procedures.

    (a) To determine whether the contract meets the threshold in FAR 
22.805(a), include the value of the basic contract plus priced options. 
A contract modification exercising a priced option is not a contract 
award under FAR 22.805(a)(1)(ii) and does not a require a preaward 
clearance.
    (b) Submit preaward review requests directly.

                  Furnishing Information to Contractors

    (c) In addition to the poster required by FAR 22.805(b), provide 
each nonexempt contractor a copy of SF 100.



Sec. 522.807  Exemptions.

    The agency labor advisor submits a request for exemption.

 PART 523_ENVIRONMENT, CONSERVATION, OCCUPATIONAL SAFETY AND DRUG-FREE 
                                WORKPLACE

  Subpart 523.3_Hazardous Materials Identification and Material Safety 
                                  Data

Sec.

Sec. 523.303  Contract clause.

Sec. 523.370  Solicitation provision.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37220, July 9, 1999, unless otherwise noted.

  Subpart 523.3_Hazardous Materials Identification and Material Safety 
                                  Data



Sec. 523.303  Contract clause.

    (a) Insert 552.223-70, Hazardous Substances, in solicitations and 
contracts for packaged items subject to the Federal Hazardous Substances 
Act and the Hazardous Materials Transportation Act.
    (b) Insert 552.223-71, Nonconforming Hazardous Materials, in 
solicitations and contracts for supplies that contain hazardous 
materials.



Sec. 523.370  Solicitation provision.

    Insert 552.223-72, Hazardous Material Information, in any 
solicitation that provides for delivery of hazardous materials on an 
f.o.b. origin basis.

                      PART 525_FOREIGN ACQUISITION

Subpart 525.1--Buy American Act-Supplies [Reserved]

                Subpart 525.3_Balance of Payments Program

Sec.

Sec. 525.302  Policy.

Sec. 525.302-70  Procurements for agencies under the Foreign Assistance 
          Act.

       Subpart 525.5_Evaluating Foreign Officers_Supply Contracts


Sec. 525.570  Procurement of hand or measuring tools or stainless steel 
          flatware for DOD.

       Subpart 525.11_Solicitation Provisions and Contract Clauses


Sec. 525.1101  Acquisition of supplies.


[[Page 193]]


    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37221, July 9, 1999, unless otherwise noted.

Subpart 525.1--Buy American Act-Supplies [Reserved]

                Subpart 525.3_Balance of Payments Program



Sec. 525.302  Policy.



Sec. 525.302-70  Procurements for agencies under the Foreign Assistance 
          Act.

    GSA procurements made directly for other agencies of items to be 
used outside the United States are made the Balance of Payments Program. 
The only exception is if GSA contracts as the agent for an agency 
governed by the Foreign Assistance Act (22 U.S.C. 2151 et seq.). If this 
exception applies, the contract will be governed by the policies and 
procedures of the agency instead of FAR 25.3 and 525.3. For example, GSA 
sometimes acts as agent for the Agency for International Development and 
the Bureau of International Narcotics Matters.

       Subpart 525.5_Evaluating Foreign Officers_Supply Contracts



Sec. 525.570  Procurement of hand or measuring tools or stainless steel 
          flatware for DOD.

    (a) Stainless steel flatware means special order and stock items of 
stainless steel flatware purchased for DOD, including, but not limited 
to, the following National Stock Numbers (NSN):


7340-00-060-6057

7340-00-205-3340

7340-00-241-8171

7340-00-559-8357

7340-00-205-3341

7340-00-241-8169

7340-00-241-8170

7340-00-688-1055

7340-00-721-6316

7340-00-721-6971

    (b) Purchases of hand or measuring tools or stainless steel flatware 
exceeding the simplified acquisition threshold by DOD must be domestic 
end products. In the case of stainless steel flatware, the Secretary of 
the Department concerned can make an exception. The individual must 
determine that a satisfactory quality and sufficient quantity produced 
in the United States or its possessions are not available when needed at 
domestic market prices.
    (c) If GSA solicitations of hand or measuring tools or stainless 
steel flatware include DOD requirements, GSA will apply the DOD 
restrictions. The bases for applying the DOD restriction to GSA 
acquisitions are:
    (1) DOD's restrictions apply to requisitions of such items from the 
GSA stock program.
    (2) The impracticality of establishing a dual supply system to 
satisfy the requirements of civilian and military agencies.
    (3) GSA may reject any offer when it is considered necessary for 
reasons of national interest.

[65 FR 41379, July 5, 2000]

       Subpart 525.11_Solicitation Provisions and Contract Clauses



Sec. 525.1101  Acquisition of supplies.

    If you include DOD requirements for hand or measuring tools or 
stainless steel flatware in the solicitation for an acquisition 
estimated to exceed the simplified acquisition threshold, insert 
552.225-70, Notice of Procurement Restriction--Hand or Measuring Tools 
or Stainless Steel Flatware, in the solicitation and resulting 
contract(s).

[65 FR 41379, July 5, 2000]

[[Page 194]]



              SUBCHAPTER E_GENERAL CONTRACTING REQUIREMENTS

                 PART 527_PATENTS, DATA, AND COPYRIGHTS

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37221, July 9, 1999, unless otherwise noted.

               Subpart 527.4_Rights in Data and Copyrights



Sec. 527.409  Solicitation provisions and contract clauses.

    Architect-Engineer Services and Construction Contracts Involving 
                       Architect-Engineer Services

    Insert the following in solicitations and contracts for architect-
engineer services and construction contracts involving architect-
engineer services:
    (a) Insert 552.227-70, Government Rights (Unlimited), instead of FAR 
52.227-17, Rights in Data-Special Works, in contracts, except if 
552.227-71 is prescribed.
    (b) If the Government requires sole property rights and exclusive 
control over the design and data, insert 552.227-71, Drawings and Other 
Data to Become Property of Government, instead of FAR 52.227-17.

                      PART 528_BONDS AND INSURANCE

           Subpart 528.2_Sureties and Other Security for Bonds

Sec.

Sec. 528.202  Acceptability of corporate sureties.

                         Subpart 528.3_Insurance


Sec. 528.310  Contract clause for work on a Government installation.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37221, July 9, 1999, unless otherwise noted.

           Subpart 528.2_Sureties and Other Security for Bonds



Sec. 528.202  Acceptability of corporate sureties.

    Corporate surety bonds must be manually signed by the Attorney-in-
Fact or officer of the surety company and the corporate seal affixed. 
You may waive failure of the surety to affix the corporate seal as a 
minor informality. (See B-184120, July 2, 1975, 75-2 CPD 9.)

                         Subpart 528.3_Insurance



Sec. 528.310  Contract clause for work on a Government installation.

    (a) Insert the clause at 552.228-70, Workers' Compensation Laws, in 
each solicitation and contract that meets all the following conditions:
    (1) The contract amount is expected to exceed the simplified 
acquisition threshold.
    (2) The contract will require work to be performed on Government 
property.
    (b) In the case of an owner-controlled insurance program, or wrap-up 
insurance, the clause will be a part of the policy holder's 
requirements.

                             PART 529_TAXES

                     Subpart 529.4_Contract Clauses

Sec.

Sec. 529.401  Domestic contracts.

Sec. 529.401-70  Purchases at or under the simplified acquisition 
          threshold.

Sec. 529.401-71  Contracts for supplies and services usable by the DC 
          Government.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37222, July 9, 1999, unless otherwise noted.

[[Page 195]]

                     Subpart 529.4_Contract Clauses



Sec. 529.401  Domestic contracts.



Sec. 529.401-70  Purchases at or under the simplified acquisition 
          threshold.

    Insert 552.229-70, Federal, State, and Local Taxes, in purchases and 
contracts estimated to exceed the micropurchase threshold, but not the 
simplified acquisition threshold.



Sec. 529.401-71  Contracts for supplies and services usable by the DC 
          Government.

    Insert 552.229-71, Federal Tax-DC Government, in solicitations and 
contracts that permit the District of Columbia Government to place 
orders.

                       PART 532_CONTRACT FINANCING

          Subpart 532.1_Non-Commercial Item Purchase Financing

Sec.

Sec. 532.111  Contract clauses for non-commercial purchases.

            Subpart 532.2_Commercial Item Purchase Financing


Sec. 532.206  Solicitation provisions and contract clauses.

                     Subpart 532.7_Contract Funding


Sec. 532.705  Contract clauses.

Sec. 532.705-1  Clauses for contracting in advance of funds.

                   Subpart 532.8_Assignment of Claims


Sec. 532.806  Contract clauses.

                      Subpart 532.9_Prompt Payment


Sec. 532.902  Definitions.

Sec. 532-905  Invoice payments.

Sec. 532.905-70  Certification of payment to subcontractors and 
          suppliers under fixed-price construction contracts.

Sec. 532.905-71  Final payment--construction and building service 
          contracts.

Sec. 532.908  Contract clauses.

Subpart 532.70_Authorizing Payment by Governmentwide Commercial Purchase 
                                  Card


Sec. 532.7001  Definition.

Sec. 532.7002  Solicitation requirements.

Sec. 532.7003  Contract clause.

             Subpart 532.71_Payments for Recurring Services


Sec. 532.7101  Definitions.

Sec. 532.7102  Applicability.

Sec. 532.7104  Contract clauses.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37222, July 9, 1999, unless otherwise noted.

          Subpart 532.1_Non-Commercial Item Purchase Financing



Sec. 532.111  Contract clauses for non-commercial purchases.

    (a) Invoice requirements. Insert 552.232-70, Invoice Requirements, 
or something substantially the same, in all solicitations and contracts 
for supplies, services, construction, architect-engineer services, or 
the acquisition of leasehold interests in real property that require the 
submission of invoices for payment. Delete subparagraph (b) of the 
clause if an Accounting Control Transaction (ACT) number is not required 
for payment.
    (b) Adjusting payments. Insert 552.232-71, Adjusting Payments, in 
all solicitations and contracts for recurring building services expected 
to exceed the simplified acquisition threshold.
    (c) Final payment. Insert 552.232-72, Final Payment, in all 
solicitations and contracts for recurring building services expected to 
exceed the simplified acquisition threshold.

            Subpart 532.2_Commercial Item Purchase Financing



Sec. 532.206  Solicitation provisions and contract clauses.

    Discounts for prompt payment. Include 552.232-8, Discounts for 
Prompt Payments, in multiple award schedule solicitations and contracts 
insted of the clause at FAR 52.232-8.

                     Subpart 532.7_Contract Funding



Sec. 532.705  Contract clauses.



Sec. 532.705-1  Clauses for contracting in advance of funds.

    Insert 552.232-73, Availability of Funds, in solicitations and 
contracts for services which are ``severable''

[[Page 196]]

when both of the following conditions apply:
    (a) The contract, or a portion of the contract, will be chargeable 
to funds of the new fiscal year.
    (b) The circumstances described in the prescriptions for FAR 52.232-
18 or 52.232-19 do not apply.

                   Subpart 532.8_Assignment of Claims



Sec. 532.806  Contract clauses.

    Insert the clause at 552.232-23, Assignment of Claims, in 
solicitations and requirements or indefinite quantity contracts under 
which more than one agency may place orders.

                      Subpart 532.9_Prompt Payment



Sec. 532.902  Definitions.

    Full cycle electronic commerce means the use of electronic data 
interchange (EDI), Internet-based invoice processing, and electronic 
funds transfer (EFT):
    (a) By the Government, to place purchase, delivery, or task orders, 
receive invoices, and pay invoices.
    (b) By the Contractor, to accept and fill orders, submit invoices, 
and receive payment.



Sec. 532.905  Invoice payments.

    (a) General and architect-engineer contracts. Before exercising the 
authority to modify the date for constructive acceptance or constructive 
approval of progress payments in the clauses listed in this section, you 
must prepare a written justification explaining why a longer period is 
necessary. An official one level above you must approve your 
justification. Determine the time needed on a case-by-case basis.
    (1) In subdivision (a)(6)(i) of the clause at FAR 52.232-25, Prompt 
Payment, do not specify a constructive acceptance period that exceeds 30 
days.
    (2) In subdivision (a)(4)(i)(A) of the clause at FAR 52.232-26, 
Prompt Payment for Fixed-Price Architect-Engineer Contracts, do not 
specify a constructive acceptance period that exceeds 30 days.
    (3) In subdivision (a)(4)(i)(B) of the clause at FAR 52.232-26, 
Prompt Payment for Fixed-Price Architect-Engineer Contracts, do not 
specify a period for constructive approval of progress payments that 
exceeds 7 days.
    (b) Construction contracts. (1) Determine on a case-by-case basis 
the time specified for payment of progress payments in subdivision 
(a)(1)(i)(A) of the clause at FAR 52.232-27, Prompt Payment for 
Construction Contracts. Justify in writing periods longer than 14 days. 
An official one level above you must approve your justification. Under 
no circumstances may more than 30 days be specified.
    (2) Determine the time to be specified in subdivision (a)(4)(i) of 
FAR clause 52.232-27, for constructive acceptance or approval, on a 
case-by-case basis. This time may not exceed 7 days unless you justify a 
longer period in writing, and obtain the approval of an official one 
level above you. Under no circumstances may more than 30 days be 
specified.
    (c) Federal Supply Service. (1) To increase efficiency and reduce 
costs to the Government, Federal Supply Service contracts under the 
Stock, Special Order, and Schedules Programs may authorize payment 
within 10 days of receipt of a proper invoice. The contract must meet 
all the following conditions:
    (i) The contractor agrees to full cycle electronic commerce.
    (ii) The contract includes FAR 52.232-33, Mandatory Information for 
Electronic Funds Transfer Payment.
    (2) The 10 day payment terms apply to each order that meets all the 
following conditions:
    (i) FSS places the order using EDI in accordance with the Trading 
Partner Agreement.
    (ii) The contractor submits EDI invoices in accordance with the 
Trading Partner Agreement or invoices through the GSA Finance Center 
Internet-based invoice process.
    (iii) A GSA Finance Center pays the invoices using EFT.
    (3) The 10 day payment terms do not apply to any order:
    (i) Placed by a GSA contracting activity other than FSS.
    (ii) Placed by or paid by another agency.

[[Page 197]]



Sec. 532.905-70  Certification of payment to subcontractors and 
          suppliers under fixed-price construction contracts.

    The contractor may use GSA Form 2419, Certification of Progress 
Payments Under Fixed-Price Construction Contracts, for the certification 
required by FAR 52.232-5.



Sec. 532.905-71  Final payment--construction and building service 
          contracts.

    The following procedures apply to construction and building service 
contracts.
    (a) Do not process the final payment on construction or building 
service contracts until the contractor submits a properly executed GSA 
Form 1142, Release of Claims. If, after repeated attempts, you are 
unable to obtain a release of claims from the contractor, you may 
process the final payment with the approval of assigned legal counsel.
    (b) The amount of final payment must include, as appropriate, 
deductions to cover any of the following:
    (1) Liquidated damages for late completion.
    (2) Liquidated damages for labor violations.
    (3) Amounts withheld for improper payment of labor wages.
    (4) The amount of unilateral change orders covering defects and 
omissions.



Sec. 532.908  Contract clauses.

    (a) Federal Supply Service. For FSS Stock, Special Order, and 
Schedules solicitations and contracts that provide payment in 10 days 
under 532.905(c):
    (1) If the contract will include FAR 52.212-4 insert the clause at 
552.232-74, Invoice Payments. GSA received a class deviation to allow 
use of 552.232-74 for commercial items.
    (2) If the contract will not include FAR 52.212-4, insert 552.232-
25, Prompt Payment, instead of FAR 552.232-25.
    (b) Leasehold Interests in Real Property. (1) Insert 552.232-75, 
Prompt Payment, in solicitations and contracts for acquiring leasehold 
interests in real property.
    (i) You may modify the date for constructive acceptance in 
subparagraph (b)(2) of the clause to specify a period longer than 7 
calendar days (but not to exceed 30 days) if necessary because of the 
nature of the services to be received, inspected or accepted by the 
Government. Prepare a written justification for specifying the longer 
period and obtain your contracting director's approval.
    (ii) Use Alternate I if the lease contract does not contain 
provisions for ordering alterations or overtime utility services.
    (2) Insert 552.232-76, Electronic Funds Transfer Payment, in 
solicitations and contracts for acquisition of leasehold interests in 
real property.
    (c) Solicitations, purchase orders, contracts, and leases over the 
micropurchase theshold. Insert 552.232-78, Payment information:
    (1) In all solicitations, purchase orders, and contracts, including 
acquisitions of leasehold interests in real property.
    (2) In task and delivery orders if the contract that the order is 
placed against does not include the clause.

[64 FR 37222, July 9, 1999, as amended at 65 FR 41379, July 5, 2000]

Subpart 532.70_Authorizing Payment by Governmentwide Commercial Purchase 
                                  Card



Sec. 532.7001  Definition.

    Governmentwide commercial purchase card has the same meaning as in 
FAR 13.101.



Sec. 532.7002  Solicitation requirements.

    (a) In solicitations for supplies and services, except FSS schedule 
solicitations, request offerors to indicate if they will accept payment 
by Governmentwide commercial purchase card. Identify the card brand(s) 
under the GSA SmartPay program that may be used to make payments under 
the contract, on the cover page or in Section L of the solicitation.
    (b) For FSS schedule contracts, identify the card brand(s) under the 
GSA SmartPay program that may be used to make payments under the 
contract in the contract award letter.
    (c) For orders placed by GSA, you may authorize payment by 
Governmentwide commercial purchase card only for orders that do not 
exceed $100,000 (see GSA Order, Guidance on

[[Page 198]]

Use of the Credit Card for Purchases (CFO 4200.1)).
    (d) Consider requesting offerors to designate different levels for 
which they may accept payment by Governmentwide commercial purchase 
card, for example:

    ``If awarded a contract under this solicitation, the offeror agrees 
to accept payment by Governmentwide commercial purchase card for orders 
of:

--$2,500 or less
--$25,000 or less
--$50,000 or less
--$100,000 or less''

[65 FR 11247, Mar. 2, 2000]



Sec. 532.7003  Contract clause.

    (a) Indefinite-delivery, indefinite-quantity (IDIQ) contracts other 
than Federal Supply Service. Insert the clause at 552.232-77, Payment by 
Governmentwide Commercial Purchase Card, in IDIQ solicitations and 
contracts for supplies and services if the contract will provide for 
payment by Governmentwide commercial purchase card as an alternative 
method of payment for orders.
    (b) Federal Supply Service Contracts. Use Alternate I of the clause 
at 552.232-77 for all FSS schedule solicitations and contracts. You may 
use the clause in other FSS IDIQ contract as appropriate.

[65 FR 11247, Mar. 2, 2000]

             Subpart 532.71_Payments for Recurring Services



Sec. 532.7101  Definitions.

    Fixed roll payment means automatic payment of fixed amounts at 
regular intervals without submission of an invoice or receiving report.



Sec. 532.7102  Applicability.

    You may use fixed roll payments in any contract that meets all four 
of the following conditions:
    (a) The contract provides for recurring services at a constant level 
for a period of at least two months.
    (b) The contract does not contain any discount items.
    (c) Payment is due 30 days following completion of the service 
month.
    (d) For a commercial item acquisition, fixed roll payments are 
consistent with customary commercial practice.



Sec. 532.7104  Contract clauses.

    (a) Noncommercial item acquisitions. For solicitations and contracts 
to be paid by fixed roll payment, include the clause at 552.232-1, 
Payments. Do not include the clauses at FAR 52.232-1, Payments, or 
552,232-70, Invoice Requirements.
    (b) Commercial item acquisitions. For solicitations and contracts to 
be paid by fixed roll payment, tailor the clause at FAR 52.212-4 by an 
addendum as noted in paragraphs (b) (1) and (2) of this section. This 
tailoring is authorized by a deviation approved on January 5, 1999.
    (1) Delete paragraph FAR 52.212-4(g), Invoice.
    (2) Add the following to paragraph FAR 52.212-4(i), Payment:

    The Government shall pay the Contractor, without submission of 
invoices or vouchers, 30 days after the service period, the prices 
stipulated in this contract for services rendered and accepted, less any 
deductions provided in this contract.

                PART 533_PROTESTS, DISPUTES, AND APPEALS

                         Subpart 533.1_Protests

Sec.

Sec. 533.103  Protests to the agency.

Sec. 533.103-72  Solicitation provisions.

                   Subpart 533.2_Disputes and Appeals


Sec. 533.211  Contracting officer's decision.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37224, July 9, 1999, unless otherwise noted.

                         Subpart 533.1_Protests



Sec. Sec. 533.103  Protests to the agency.



Sec. Sec. 533.103-72  Solicitation provisions.

    Include the provision at 552.233-70, Protests Filed Directly With 
the General Services Administration, in each solicitation for either:
    (a) Supplies, services, construction, or architect-engineer services 
expected to exceed the simplified acquisition threshold.

[[Page 199]]

    (b) Acquisition of leasehold interests in real property expected to 
exceed the simplified lease acquisition threshold.

                   Subpart 533.2_Disputes and Appeals



Sec. Sec. 533.211  Contracting officer's decision.

    In addition to the information in FAR 33.211(a)(4)(v), advise the 
contractor in your written decision that a notice of appeal must:
    (a) Describe the nature of the dispute and the relief sought, the 
contract provisions involved, and any other additional information or 
comments relating to the dispute considered important.
    (b) Be signed personally by the appellant (the prime contractor 
making the appeal) or by an officer of the appellant corporation, or 
member of the appellant firm, or by the contractor's duly authorized 
representative or attorney.

[[Page 200]]



             SUBCHAPTER F_SPECIAL CATEGORIES OF CONTRACTING

         PART 536_CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS

                          Subpart 536.1_General

Sec.

Sec. 536.101  Applicability.

      Subpart 536.2_Special Aspects of Contracting for Construction


Sec. 536.213  Special procedures for sealed bidding in construction 
          contracting.

Sec. 536.213-3  Invitations for bids.

Sec. 536.213-370  Bids that include alternates.

Sec. 536.213-371  Bids that include options.

Sec. 536.213-372  Bids that include both alternates and options.

Sec. 536.270  Exercise of options.

Sec. 536.271  Project labor agreements.

                     Subpart 536.5_Contract Clauses


Sec. 536.570  Supplemental provisions and clauses.

Sec. 536.570-1  Definitions.

Sec. 536.570-2  Authorities and limitations.

Sec. 536.570-3  Specialist.

Sec. 536.570-4  Basis of award--construction contract.

Sec. 536.570-5  Working hours.

Sec. 536.570-6  Use of premises.

Sec. 536.570-7  Measurements.

Sec. 536.570-8  Specifications and drawings.

Sec. 536.570-9  Shop drawings, coordination drawings, and schedules.

Sec. 536.570-10  Samples.

Sec. 536.570-11  Heat.

Sec. 536.570-12  Use of equipment by the Government.

Sec. 536.570-13  Subcontracts.

Sec. 536.570-14  Requirement for a Project Labor Agreement.

                Subpart 536.6_Architect-Engineer Services


Sec. 536.602  Selection of firms for architect-engineer contracts.

Sec. 536.602-1  Selection criteria.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37224, July 9, 1999, unless otherwise noted.

                          Subpart 536.1_General



Sec. 536.101  Applicability.

    If a requirement in this part is inconsistent with a requirement in 
another GSAR part, this part takes precedence.

      Subpart 536.2_Special Aspects of Contracting for Construction



Sec. 536.213  Special procedures for sealed bidding in construction 
          contracting.



Sec. 536.213-3  Invitations for bids.



Sec. 536.213-370  Bids that include alternates.

    (a) The base bid must include all features essential to a sound and 
adequate building design. If it appears that funds available for a 
project may be insufficient to include all desired features in the base 
bid, you may issue a solicitation for a base bid and include one or more 
alternates in the order of priority. Use alternates only if they are 
clearly justified and involve substantial amounts of work in relation to 
the base bid. Their use must be limited and should involve only ``add'' 
alternates.
    (b) Before opening bids that include alternates, determine, and 
record in the contract file, the amount of funds available for the 
project. The amount recorded must be announced at the beginning of the 
bid opening. The amount is the controlling factor in determining the low 
bidder. This amount may be increased later when determining the 
alternate items to award to the low bidder if the following condition is 
met: the award amount of the base bid plus the combination of alternate 
items does not exceed the amount offered for the base bid and the same 
combination of alternate items by any other responsible bidder whose bid 
conforms to the solicitation. This requirement prevents the displacement 
of the low bidder by manipulating the alternates to be used.



Sec. 536.213-371  Bids that include options.

    (a) Subject to the limitations in paragraph (c) of this section, you 
may include options in contracts if it is in the Government's interest.
    (b) the appropriate use of options may include, but is not limited 
to, any of the following:
    (1) If additional work is anticipated but funds are not expected to 
be available at the time of award, and it would

[[Page 201]]

not be practicable to award a separate contract or to permit an 
additional contractor to work on the same site.
    (2) If fixed building equipment, e.g. elevators or escalators, will 
be installed under the construction contract and it is advantageous to 
have the installer of the equipment maintain and service the equipment 
during the warranty period.
    (c) You must not use options under any of the following conditions:
    (1) the prospective option represents known firm requirements for 
which funds are available unless competition for the option quantity is 
impracticable once the initial contract is awarded.
    (2) The contractor will incur undue risks; e.g., the price or 
availability of necessary materials or labor is not reasonably 
foreseeable.
    (d) Solicitations containing option provisions must state the period 
within which the options may be exercised.
    (e) Solicitations must state whether the basis of award is inclusive 
or exclusive of the options. Before issuing a solicitation that includes 
evaluated options, you must determine that there is reasonable certainty 
that funds will be made available to permit exercise of the option.



Sec. 536.213-372  Bids that include both alternates and options.

    (a) Solicitations may include both alternates and options if the 
conditions in 536.213-370, Bids that include alternates, and 536.213-
371, Bids that include options, are satisfied. In these solicitations, 
the low bidder for purposes of award is the responsible bidder offering 
the lowest aggregate price for the base bid and the alternates, in the 
order of priority listed in the solicitation, that provide the most work 
features within the funds available at bid opening, plus all options 
designated to be evaluated.
    (b) The basis of award may require the evaluation of options 
associated with alternates if the related alternate is selected.
    (c) Before opening bids that include both alternates and options, 
determine, and record in the contract file, the amount of funds 
available for the project (i.e., for the base bid and alternate work). 
The amount recorded must be announced at the beginning of the bid 
opening. This amount may be increased later when determining the 
alternate items to be awarded to the low bidder if the following 
condition is met: the award amount of the base bid and evaluated options 
plus the alternate items does not exceed the amount offered for the base 
bid, the evaluated options, and the same combination of alternate items 
by any other responsible bidder whose bid conforms to the solicitation.



Sec. 536.270  Exercise of options.

    (a) If exercising an option, notify the contractor, in writing, 
within the time period specified in the contract.
    (b) Exercise options only after determining that all the following 
conditions exist:
    (1) Funds are available.
    (2) The requirement covered by the option fulfills an existing 
Government need.
    (3) Exercising the option is the most advantageous method of 
satisfying the Government's need, price and other factors considered.
    (c) Before exercising an option, you must determine that the action 
complies with the option's terms and this section's requirements. 
Include your written determination in the contract file.
    (d) The contract modification, or other written document which 
notifies the contractor of the exercise of the option, must cite the 
option clause as authority. If exercising an unpriced or unevaluated 
option, cite the statutory authority permitting the use of other than 
full and open competition (see FAR 6.302 and 517.207).



Sec. 536.271  Project labor agreements.

    (a) Authority. This subpart implements the Presidential memorandum 
of June 5, 1997, on using project labor agreements (PLAs) on Federal 
construction projects. The Presidential memorandum authorizes executive 
departments and agencies to require PLAs on large and significant 
construction projects for facilities to be owned by a Federal department 
or agency.
    (b) Applicability. These policies and procedures apply to all GSA 
activities

[[Page 202]]

authorized to award contracts for construction of facilities to be owned 
by a Federal department or agency. You may use a PLA in leasehold 
arrangement, Federally funded projects, and other appropriate 
circumstances.
    (c) Definitions. Construction means construction, alteration, or 
repair (including dredging, excavating, and painting) of buildings, 
structures, or other real property. The terms buildings, structures, or 
other real property are defined further in Federal Acquisition 
Regulation (FAR) 36.102.
    Labor organization means a labor organization engaged in an industry 
affecting commerce, and any agent of such an organization, and includes 
any organization of any kind, and any agency, or employee representation 
committee, group, association, or plan so engaged in which employees 
participate and which exists for the purpose, in whole or in part, of 
dealing with employers concerning grievances, labor disputes, wages, 
rates of pay, hours, or other terms or conditions of employment, and any 
conference, general committee, joint or system board, or joint council 
so engaged which is subordinate to a national or international labor 
organization (42 U.S.C. 2000e(d)).
    Large and significant project means a Federal construction project 
with a total cost to the Federal Government of more than $5 million.
    Project Labor Agreement (PLA) means an agreement between the 
contractor, subcontractors, and the union(s) representing workers. Under 
a PLA, the contractor and subcontractors on a project and the union(s) 
agree on terms and conditions of employment for the project, 
establishing a framework for labor-management cooperation to advance the 
Government's procurement interest in cost, efficiency, and quality.
    (d) Policy. (1) You may, on a project-by-project basis, use a PLA on 
a large and significant project when both of the following conditions 
apply:
    (i) A PLA will advance the Government's procurement interests.
    (ii) No laws that apply to the specific construction project 
preclude the use of the PLA.
    (2) Do not require any contractor to enter into a PLA with any 
particular labor organization.
    (3) The use of a PLA is not intended to create any right or benefit, 
substantive or procedural enforceable by a nonfederal party against the 
United States, its departments, and agencies, its officers or employees, 
or any other person.
    (e) Procedures. (1) As part of procurement planning for construction 
projects with a total estimated cost to the Federal Government of more 
than $5 million, you may consider requiring a PLA.
    (2) To require a PLA, you must determine whether use of a PLA will 
advance the Government's procurement interests in all the following 
areas:
    (i) Cost, efficiency, and quality.
    (ii) Promoting labor-management stability.
    (iii) Promoting compliance with applicable legal requirements 
governing safety and health, equal employment opportunity, labor and 
employment standards, and other matters.
    (3) In making the determination required by paragraph (b) of this 
section, consult with the agency project or program manager and obtain 
guidance from the Agency Labor Advisor and assigned legal counsel. You 
should consider the following factors:
    (i) Whether past experience with construction projects in the 
location where the project will be performed indicates that a PLA will 
be effective.
    (ii) Whether delays in performance of the construction contract 
would have significant adverse impact on the mission of the agency or 
operation of the installation or facility.
    (iii) Whether any law applies to the specific construction project 
that would impede use of a PLA.
    (iv) Whether the labor organizations in the area can provide a 
reliable source of skilled, experienced building trades workers in all 
crafts needed on the job site for the project's duration (taking into 
consideration other major construction work in the area).
    (v) Whether the Government can benefit from uniform work rules and 
working conditions and established procedures for resolving labor 
disputes, no strike/no lock-out protections.
    (vi) Whether the Government can benefit from increased stability and

[[Page 203]]

labor peace that derives from greater labor-management cooperation.
    (vii) Whether the requirements for a PLA will unreasonably restrict 
competition.
    (viii) Other relevant information.
    (4) Document the rationale supporting your decision to require a PLA 
in the contract file.
    (5) Provide the following information to the Agency Labor Advisor 
(GSA Acquisition Policy Division (MVP)):
    (i) A brief description of the project.
    (ii) The estimated cost.
    (iii) A copy of the document supporting your decision to require a 
PLA.
    (iv) A copy of the solicitation.

                     Subpart 536.5_Contract Clauses



Sec. 536.570  Supplemental provisions and clauses.



Sec. 536.570-1  Definitions.

    Insert 552.236-70, Definitions, in solicitations and contracts if 
construction, dismantling, demolition, or removal of improvements is 
contemplated.



Sec. 536.570-2  Authorities and limitations.

    Insert 552.236-71, Authorities and Limitations, in solicitations and 
contracts if construction, dismantling, demolition, or removal of 
improvements is contemplated and the contract amount is expected to 
exceed the simplified acquisition threshold.



Sec. 536.570-3  Specialist.

    Insert 552.236-72, Specialist, in solicitations and contracts for 
construction if the technical sections of the contract require unusual 
experience or specialized facilities for adequate contract performance.



Sec. 536.570-4  Basis of award--construction contract.

    (a) Insert a provision substantially the same as 552.236-73, Basis 
of Award--Construction Contract, in solicitations for fixed-price 
construction contracts except if any of the following conditions apply:
    (1) The solicitation requires the submission of a lump-sum bid only.
    (2) The solicitation is for an indefinite quantity contract.
    (3) The contract amount is not expected to exceed the simplified 
acquisition threshold.
    (b) Instructions for use.

------------------------------------------------------------------------
     If the solicitation requests the
          submission of a . . .                  Then use the . . .
------------------------------------------------------------------------
(1) Base bid and unit prices.............  Basic provision.
(2) Base bid and options.................  Provision with its Alternate
                                            I.
(3) Base bid and alternates..............  Provision with its Alternate
                                            II.
(4) Base bid, alternates, and options....  Provision with its Alternate
                                            III.
------------------------------------------------------------------------



Sec. 536.570-5  Working hours.

    Insert 552.236-74, Working Hours, in solicitations and contracts if 
construction, dismantling, demolition, or removal of improvements is 
contemplated and the contract amount is expected to exceed the 
simplified acquisition threshold.



Sec. 536.570-6  Use of premises.

    Insert 552.236-75, Use of Premises, in solicitations and contracts 
if construction, dismantling, demolition, or removal of improvements is 
contemplated.



Sec. 536.570-7  Measurements.

    Insert 552.236-76, Measurements, in solicitations and contracts if 
construction, dismantling, demolition, or removal of improvements is 
contemplated.



Sec. 536.570-8  Specifications and drawings.

    Insert the clause at 552.236-77, Specifications and Drawings, in 
solicitations and contracts if construction, dismantling, demolition, or 
removal of improvements is contemplated and the contract amount is 
expected to exceed the simplified acquisition threshold.



Sec. 536.570-9  Shop drawings, coordination drawings, and schedules.

    Insert the clause at 552.236-78, Shop Drawings, Coordination 
Drawings, and Schedules, in solicitations and contracts if construction 
is contemplated and the contract amount is expected to exceed the 
simplified acquisition threshold.



Sec. 536.570-10  Samples.

    Insert the clause at 552.236-79, Samples, in solicitations and 
contracts for construction if the technical sections

[[Page 204]]

of the contract require the submission and approval of samples.



Sec. 536.570-11  Heat.

    Insert the clause at 552.236-80, Heat, in solicitations and 
contracts if construction, dismantling, demolition, or removal of 
improvements is contemplated.



Sec. 536.570-12  Use of equipment by the Government.

    Insert the clause at 552.236-81, Use of Equipment by the Government, 
in contracts requiring heating and air-conditioning of existing 
buildings if it may be necessary for the Government to operate all or 
part of the equipment before final acceptance of the contract.



Sec. 536.570-13  Subcontracts.

    Insert 552.236-82, Subcontracts, in solicitations and contracts for 
construction if the contract amount is expected to exceed the simplified 
acquisition threshold.



Sec. 536.570-14  Requirement for a Project Labor Agreement.

    Insert a clause substantially the same as 552.236-83, Requirement 
for a Project Labor Agreement, in solicitations and contracts that will 
require a project labor agreement.

                SUBPART 536.6_Architect-Engineer Services



Sec. 536.602  Selection of firms for architect-engineer contracts.



Sec. 536.602-1  Selection criteria.

    (a) FAR 36.602-1 requires that agencies include ``location in the 
general geographical area of the project and knowledge of locality of 
the project'' as one of several selection criteria.
    (1) Do not use this evaluation factor as a minimum qualification 
requirement for determining whether a firm is eligible to compete for a 
proposed project.
    (2) This factor must not exceed 5 percent of the total weight of all 
evaluation criteria. In order to receive maximum score for this factor, 
the architect-engineer firm(s) must demonstrate that at least 35 percent 
of the architect-engineer contract services (based on the total contract 
price) will be accomplished within the geographical boundaries 
established for the project.
    (3) Under an approved class deviation from FAR 36.602-1(a)(5), this 
factor does not apply to projects that the Chief Architect of GSA 
determines have national significance.
    (b) The public announcement (Commerce Business Daily notice) for a 
proposed project should identify the general geographical area of the 
project by either:
    (1) A radius in miles or other appropriate unit of measure.
    (2) The Standard Metropolitan Statistical Area, county(ies), 
state(s) surrounding the project, or other appropriate geographic 
boundaries.
    (c) Architect-engineer selections under the Design Excellence 
Program must apply the geographical evaluation criteria in the second 
phase.
    (d) The public announcement (Commerce Business Daily notice) must 
provide the number of calendar days the architect-engineer of record has 
to establish a production capability within the general geographical 
area of the project. You may allow the architect-engineer of record up 
to 45 calendar days after contract award to establish this production 
capability.

[65 FR 11247, Mar. 2, 2000]

                      PART 537_SERVICE CONTRACTING

                 Subpart 537.1_Service Contracts_General

Sec.

Sec. 537.101  Definitions.

Sec. 537.110  Solicitation provisions and contract clauses.

             Subpart 537.2_Advisory and Assistance Services


Sec. 537.270  Contract clause.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37226, July 9, 1999, unless otherwise noted.

                 Subpart 537.1_Service Contracts_General



Sec. 537.101  Definitions.

    Contracts for building services means contracts for services 
relating to the

[[Page 205]]

operation and maintenance of a building (for example, janitorial; window 
washing; snow removal; trash removal; lawn and grounds care; inspection, 
maintenance and repair of fixed equipment (e.g., elevators, air-
conditioning, hearing systems)) and protection or guard service.



Sec. 537.110  Solicitation provisions and contract clauses.

    The following provision and clauses apply to contracts for building 
services:
    (a) If the contract is expected to exceed the simplified acquisition 
threshold and it is not initiated under the Javits-Wagner-O'Day Act:
    (1) Insert 552.237-70, Qualifications of Offerors, in the 
solicitation.
    (2) Insert 552.237-71, Qualifications of Employees, in the 
solicitation and contract. If needed, use supplemental provisions or 
clauses to describe specific requirements for employees performing work 
on the contract.
    (b) Insert 552.237-72, Prohibition Regaring ``Quasi-Military Armed 
Forces,'' in solicitations and contracts for guard service.

[65 FR 41379, July 5, 2000]

             Subpart 537.2_Advisory and Assistance Services



Sec. 537.270  Contract clause.

    Insert the clause at 552.237-73, Restriction on Disclosure of 
Information, in solicitations and contracts for proposal evaluation and 
analysis services.

              PART 538_FEDERAL SUPPLY SCHEDULE CONTRACTING

  Subpart 538.2_Establishing and Administering Federal Supply Schedules

Sec.

Sec. 538.270  Evaluation of multiple award schedule (MAS) offers.

Sec. 538.271  MAS contract awards.

Sec. 538.272  MAS price reductions.

Sec. 538.273  Contract clauses.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37227, July 9, 1999, unless otherwise noted.

  Subpart 538.2_Establishing and Administering Federal Supply Schedules



Sec. 538.270  Evaluation of multiple award schedule (MAS) offers.

    (a) The Government will seek to obtain the offeror's best price (the 
best price given to the most favored customer). However, the Government 
recognizes that the terms and conditions of commercial sales vary and 
there may be legitimate reasons why the best price is not achieved.
    (b) Establish negotiation objectives based on a review of relevant 
data and determine price reasonableness.
    (c) When establishing negotiation objectives and determining price 
reasonableness, compare the terms and conditions of the MAS solicitation 
with the terms and conditions of agreements with the offeror's 
commercial customers. When determining the Government's price 
negotiation objectives, consider the following factors:
    (1) Aggregate volume of anticipated purchases.
    (2) The purchase of a minimum quantity or a pattern of historic 
purchases.
    (3) Prices taking into consideration any combination of discounts 
and concessions offered to commercial customers.
    (4) Length of the contract period.
    (5) Warranties, training, and/or maintenance included in the 
purchase price or provided at additional cost to the product prices.
    (6) Ordering and delivery practices.
    (7) Any other relevant information, including differences between 
the MAS solicitation and commercial terms and conditions that may 
warrant differentials between the offer and the discounts offered to the 
most favored commercial customer(s). For example, an offeror may incur 
more expense selling to the Government than to the customer who receives 
the offeror's best price, or the customer (e.g., dealer, distributor, 
original equipment manufacturer, other reseller) who receives the best 
price may perform certain value-added functions for the offeror that the 
Government does not perform. In such cases, some reduction in the 
discount

[[Page 206]]

given to the Government may be appropriate. If the best price is not 
offered to the Government, you should ask the offeror to identify and 
explain the reason for any differences. Do not require offerors to 
provide detailed cost breakdowns.
    (d) You may award a contract containing pricing which is less 
favorable than the best price the offeror extends to any commercial 
customer for similar purchases if you make a determination that both of 
the following conditions exist:
    (1) The prices offered to the Government are fair and reasonable, 
even though comparable discounts were not negotiated.
    (2) Award is otherwise in the best interest of the Government.



Sec. 538.271  MAS contract awards.

    (a) MAS awards will be for commercial items as defined in FAR 2.101. 
Negotiate contracts as a discount from established catalog prices.
    (b) Before awarding any MAS contract, determine that the offered 
prices are fair and reasonable (see FAR subpart 15.4 and 538.270). 
Document the negotiation and your determination using FAR 15.406-3 as 
guidance.
    (c) State clearly in the award document the price/discount 
relationship between the Government and the identified commercial 
customer (or category of customers) on which the award is predicated.



Sec. 538.272  MAS price reductions.

    (a) Section 552.238-75, Price Reductions, requires the contractor to 
maintain during the contract period the negotiated price/discount 
relationship (and/or term and condition relationship) between the 
Government and the offeror's customer or category of customers on which 
the contract award was predicated (see 538.271(c)). If a change occurs 
in the contractor's commercial pricing or discount arrangement 
applicable to the identified commercial customer (or category of 
customers) that results in a less advantageous relationship between the 
Government and this customer or category of customers, the change 
constitutes a ``price reduction.''
    (b) Make sure that the contractor understands the requirements of 
section 552.238-75 and agrees to report to you all price reductions as 
provided for in the clause.



Sec. 538.273  Contract clauses.

    (a) Multiple award schedules. Insert in solicitations and contracts:
    (1) 552.238-70, Identification of Electronic Office Equipment 
Providing Accessibility for the Handicapped, if you include electronic 
office equipment items.
    (2) 552.238-71, Submission and Distribution of Authorized FSS 
Schedule Pricelists. If GSA is not prepared to accept electronic 
submissions for a particular schedule delete:
    (i) Subparagraphs (c)(1)(ii) and (c)(3).
    (ii) The subparagraph identifier ``(i)'' in (c)(1) and the word 
``and'' at the end of subparagraph (i).
    (3) 552.238-72, Identification of Energy-Efficient Office Equipment 
and Supplies Containing Recovered Materials or Other Environmental 
Attributes.
    (4) 552.238-73, Cancellation.
    (b) Multiple and single award schedules. Insert in solicitations and 
contracts:
    (1) 552.238-74, Contractor's Report of Sales.
    (2) 552.238-75, Price Reductions.
    (3) 552.238-76, Industrial Funding Fee.

[[Page 207]]



                    SUBCHAPTER G_CONTRACT MANAGEMENT

           PART 542_CONTRACT ADMINISTRATION AND AUDIT SERVICES

          Subpart 542.11_Production Surveillance and Reporting

Sec.

Sec. 542.1107  Contract clause.

            Subpart 542.15_Contractor Performance Information


Sec. 542.1503  Procedures.

Sec. 542.1503-71  Information to collect.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37228, July 9, 1999, unless otherwise noted.

          Subpart 542.11_Production Surveillance and Reporting



Sec. 542.1107  Contract clause.

                   FSS Stock or Special Order Program

    Insert 552.242-70, Status Report of Orders and Shipments, in 
solicitations and indefinite quantity and requirements contracts for 
stock or special order program items. You also may use the clause in 
indefinite delivery definite quantity contracts for stock or special 
order program items when close monitoring is necessary because numerous 
shipments are involved.

            Subpart 542.15_Contractor Performance Information



Sec. 542.1503  Procedures.



Sec. 542.1503-71  Information to collect.

    The system for collecting contractor performance data should 
include, as appropriate:
    (a) Timeliness of delivery or performance, for example:
    (1) Adherence to contract delivery schedules.
    (2) Resolution of delays
    (3) Number of ``show cause'' letters and ``cure notices'' issued.
    (4) Number of delinquent deliveries.
    (5) Number of contract extensions resulting from contractor-caused 
delays.
    (6) Timely submission or performance or required tests.
    (b) Conformance of product or service to contract requirements, for 
example:
    (1) Quality of workmanship.
    (2) Reliability.
    (3) Adequacy of correction of defects.
    (4) Number of safety defects.
    (5) Number of product rejections.
    (6) Results of laboratory tests.
    (7) Number and extent of warranty problems.
    (c) Customer comments, for example:
    (1) Number and quality of positive comments.
    (2) Number and nature of complaints.
    (3) Adequacy of resolving customer complaints.
    (d) Terminations for default.
    (e) On-the-job safety performance record, including the number of 
lost or restricted workdays due to occupational injuries in comparison 
to the national average.
    (f) Adequacy of contractor's quality assurance system.
    (g) Compliance with other key contract provisions, for example:
    (1) Subcontracting program.
    (2) Labor standards.
    (3) Safety standards.
    (4) Reporting requirements.
    (h) Exhibiting customer-oriented behavior.
    (i) Other performance elements identified by the Service.

                     PART 543_CONTRACT MODIFICATIONS

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37228, July 9, 1999, unless otherwise noted.

                       Subpart 543.2_Change Orders



Sec. 543.205  Contract clauses.

    (a) Construction. (1) Insert 552.243-70, Pricing of Adjustments, in 
solicitations and contracts if the contract:
    (i) Amount is expected to exceed the simplified acquisition 
threshold.
    (ii) Will be other than a cost type.
    (2) Insert 552.243-71, Equitable Adjustments, in solicitations and 
contracts containing FAR 52.243-4.

[[Page 208]]

    (b) Multiple award schedules (MAS). Insert 552.243-72, Modifications 
(Multiple Award Schedule), in MAS solicitations and contracts issued by 
GSA. For solicitations and contracts issued under Federal Supply 
Classification (FSC) 65 you may use the clause with its Alternate I for 
products ordered from authorized Prime Vendors.

                       PART 546_QUALITY ASSURANCE

                     Subpart 546.3_Contract Clauses

Sec.

Sec. 546.302  Fixed-price supply contracts.

Sec. 546.302-70  Source inspection by Quality Approved Manufacturer.

Sec. 546.302-71  Source inspection.

Sec. 546.312  Construction contracts.

           Subpart 546.4_Government Contract Quality Assurance


Sec. 546.470-2  Certification testing.

                        Subpart 546.7_Warranties


Sec. 546.708  Warranties of data.

Sec. 546.710  Contract clauses.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37228, July 9, 1999, unless otherwise noted.

                     Subpart 546.3_Contract Clauses



Sec. 546.302  Fixed-price supply contracts.



Sec. 546.302-70  Source inspection by Quality Approved Manufacturer.

    For contracts and solicitations issued by FSS:
    (a) Insert the clause at 552.246-70, Source Inspection by Quality 
Approved Manufacturer, in solicitations and contracts that provide for 
source inspection, except:
    (1) Multiple award schedule contracts.
    (2) Motor vehicle contracts.
    (3) Contracts awarded by the FSS Services Acquisition Center, unless 
you decide, together with the Central Office Quality Assurance Division 
(FQA), that inspection by Government personnel is necessary.
    (b) You may authorize inspection and testing at manufacturing plants 
or other facilities located outside the United States, Puerto Rico, or 
the Virgin Islands, under paragraph (a)(1) of the clause at 552.246-70 
under any of the circumstances listed in this paragraph. Coordinate the 
authorization with FQA and document it in the file.
    (1) Inspection services are available from another Federal agency 
with primary inspection responsibility in the geographic area.
    (2) An inspection interchange agreement exists with another agency 
for inspection at a contractor's plant.
    (3) The procurement is for the Agency for International Development 
and specifies the area of source.
    (4) Other considerations will ensure more economical and effective 
inspection consistent with the Government's interest.



Sec. 546.302-71  Source inspection.

    For solicitations and contracts issued by FSS, if Government 
personnel at the source will perform inspection, insert 552.246-71, 
Source Inspection by Government.



Sec. 546.312  Construction contracts.

    Insert the clause at 552.246-72, Final Inspection and Tests, in 
solicitations and contracts for construction that include FAR 52.246-12, 
Inspection of Construction.

           Subpart 546.4_Government Contract Quality Assurance



Sec. 546.470-2  Certification testing.

    Certification testing determines whether an item conforms with a 
specification for the purpose of executing a certificate of compliance 
required by the specification. The contractor has responsibility for 
certification testing.

                        Subpart 546.7_Warranties



Sec. 546.708  Warranties of data.

    (a) Use warranties of data only when you meet both of the following 
conditions:
    (1) You decide the use of a warranty is in the Government's 
interest.
    (2) The contracting director concurs in your decision.
    (b) The technical or specification manager has responsibility for 
developing any warranties of data.

[[Page 209]]



Sec. 546.710  Contract clauses.

    (a) Insert the clause at 552.246-17, Warranty of Supplies of a 
Noncomplex Nature, instead of FAR 52.246-17 in solicitations and 
contracts. Use the following alternates as applicable:
    (1) Commercial item acquisitions other than multiple award 
schedules. Use the clause at 552.246-17 with its Alternate I.
    (2) Other than commercial items in Class 8010. Use the clause at 
552.246-17 with its Alternate II.
    (3) Other than commercial items in Class 8030 or 8040. Use the 
clause at 552.246-17 with its Alternate III. In addition, specify in the 
solicitation whether the items are ``noncritical end use items'' or 
``critical end use items''.
    (b) Multiple award schedules. Insert the clause at 552.246-73, 
Warranty--Multiple Award Schedule, in solicitations and contracts.
    (c) Construction contracts expected to exceed the simplified 
acquisition threshold. Insert the clause at 552.246-75, Guarantees, in 
solicitations and contracts.
    (d) Pesticides. Insert the clause at 552.246-76, Warranty of 
Pesticides, in solicitations and contracts involving the procurement of 
pesticides.

[64 FR 37228, July 9, 1999, as amended at 65 FR 11248, Mar. 2, 2000]

                         PART 547_TRANSPORTATION

            Subpart 547.3_Transportation in Supply Contracts

Sec.

Sec. 547.300  Scope of subpart.

Sec. 547.303  Standard delivery terms and contract clauses.

Sec. 547.303-1  F.o.b origin.

Sec. 547.304  Determination of delivery terms.

Sec. 547.304-5  Exceptions.

Sec. 547.305  Solicitation provisions, contract clauses, and 
          transportation factors.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37229, July 9, 1999, unless otherwise noted.

            Subpart 547.3_Transportation in Supply Contracts



Sec. 547.300  Scope of subpart.

    This subpart applies to FSS acquisitions.



Sec. 547.303  Standard delivery terms and contract clauses.



Sec. 547.303-1  F.o.b origin.

                       Contractor Responsibilities

    The contractor must both:
    (a) Request a carrier routing from the applicable transportation 
zone office on all shipments weighing 10,000 pounds or more.
    (b) Mail the original of the commercial bill of lading (CBL), to the 
office that authorized the CBL (applies to shipment on a CBL). Ensure 
that the signature of the carrier's agent and the annotation required by 
FAR 52.247-1 appear on the original and all copies of the CBL.



Sec. 547.304  Determination of delivery terms.



Sec. 547.304-5  Exceptions.

    (a) Solicitations that provide for delivery to Alaska, Hawaii, or 
Puerto Rico. Include notice that the offeror may specify delivery f.o.b. 
origin; f.o.b. vessel, part of shipment; f.o.b. destination; or any 
combination of these. If appropriate, provide for other delivery terms.
    (b) Federal Supply Schedules. If f.o.b. destination is offered for 
delivery within CONUS, attempt to obtain the same delivery term for 
shipment to Alaska, Hawaii, or Puerto Rico.



Sec. 547.305  Solicitation provisions, contract clauses, and 
          transportation factors.

    (a) Insert 552.247-70, Placarding Railcar Shipments, in 
solicitations and contracts if it is essential that the railcar doors be 
especially positioned next to the unloading dock, platform, or warehouse 
door.
    (b) Insert 552.247-71, Diversion of Shipment Under f.o.b. 
Destination Contracts, in Stock, Special Order Program (SOP), and Single 
Award Schedule solicitations and contracts which provide for f.o.b. 
destination shipment.

                    PART 549_TERMINATION OF CONTRACTS

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37229, July 9, 1999, unless otherwise noted.

[[Page 210]]

               Subpart 549.5_Contract Termination Clauses



Sec. 549.502  Termination for convenience of the Government.

    Acquisitions Funded Through the Information Technology (IT) Fund

    (a) You may use the clause at 552.249-70, Termination for 
Convenience of the Government (Fixed-Price) (Short Form), when 
appropriate, in solicitations and contracts for the acquisition and 
maintenance of telephone systems funded through the Information 
Technology (IT) Fund. Use this clause with FAR 52.249-1 or FAR 52.249-3 
and 52.249-4.
    (b) If you use the clause at 552.249-70, you must also insert 
552.249-71, Submission of Termination Liability Schedule, in the 
solicitation and contract.

[[Page 211]]



                     SUBCHAPTER H_CLAUSES AND FORMS

          PART 552_SOLICITATION PROVISIONS AND CONTRACT CLAUSES

Sec.

Sec. 552.000  Scope of part.

       Subpart 552.1_Instructions for Using Provisions and Clauses


Sec. 552.101-70  Using part 552.

Sec. 552.102  Incorporating provisions and clauses.

Sec. 552.103  Identification of provisions and clauses.

Sec. 552.104  Procedures for modifying and completing provisions and 
          clauses.

Sec. 552.105  Procedures for using alternates.

Sec. 552.107-70  Provisions and clauses prescribed in subpart 552.1.

              Subpart 552.2_Text of Provisions and Clauses


Sec. 552.200  Scope of subpart.

Sec. 552.203-5  Covenant Against Contingent Fees.

Sec. 552.203-70  Price Adjustment for Illegal or Improper Activity.

Sec. 552.203-71  Restriction on Advertising.

Sec. 552.209-70  Product Removal from Qualified Products List.

Sec. 552.209-71  Waiver of First Article Testing and Approval 
          Requirement.

Sec. 552.209-72  Supplemental Requirements for First Article Approval--
          Contractor Testing.

Sec. 552.209-73  Supplemental Requirements for First Article Approval--
          Government Testing.

Sec. 552.211-8  Time of Delivery.

Sec. 552.211-70  [Reserved]

Sec. 552.211-71  Standard References.

Sec. 552.211-72  Reference to Specifications in Drawings.

Sec. 552.211-73  Marking.

Sec. 552.211-74  Charges for Marking.

Sec. 552.211-75  Preservation, Packaging and Packing.

Sec. 552.211-76  Charges for Packaging and Packing.

Sec. 552.211-77  Packing List.

Sec. 552.211-78  Commercial Delivery Schedule (Multiple Award Schedule).

Sec. 552.211-79  Acceptable Age of Supplies.

Sec. 552.211-80  Age on Delivery.

Sec. 552.211-81  Time of Shipment.

Sec. 552.211-82  Notice of Shipment.

Sec. 552.211-83  Availability for Inspection, Testing, and Shipment/
          Delivery.

Sec. 552.211-84  Non-Compliance With Contract Requirements.

Sec. 552.212-70  Preparation of Offer (Multiple Award Schedule).

Sec. 552.212-71  Contract Terms and Conditions Applicable to GSA 
          Acquisition of Commercial Items.

Sec. 552.212-72  Contract Terms and Conditions Required To Implement 
          Statutes or Executive Orders Applicable to GSA Acquisition of 
          Commercial Items.

Sec. 552.212-73  Evaluation--Commerical Items (Multiple Award Schedule).

Sec. 552.214-70  ``All or None'' Offers.

Sec. 552.214-71  Progressive Awards and Monthly Quantity Allocations.

Sec. 552.214-72  Bid Sample Requirements.

Sec. 552.215-70  Examination of Records by GSA.

Sec. 552.215-71  Examination of Records by GSA (Multiple Award 
          Schedule).

Sec. 552.215-72  Price Adjustment--Failure to Provide Accurate 
          Information.

Sec. 552.216-70  Economic Price Adjustment--FSS Multiple Award Schedule 
          Contracts.

Sec. 552.216-71  Economic Price Adjustment--Stock and Special Order 
          Program Contracts.

Sec. 552.216-72  Placement of Orders.

Sec. 552.216-73  Ordering Information.

Sec. 552.217-70  Evaluation of Options.

Sec. 552.217-71  Notice Regarding Option(s).

Sec. 552.219-70  Allocation of Orders--Partially Set-Aside Items.

Sec. 552.219-71  Notice to Offerors of Subcontracting Plan Requirements.

Sec. 552.219-72  Preparation, Submission, and Negotiation of 
          Subcontracting Plans.

Sec. 552.219-73  Goals for Subcontracting Plan.

Sec. 552.219-74  Section 8(a) Direct Award.

Sec. 552.223-70  Hazardous Substances.

Sec. 552.223-71  Nonconforming Hazardous Materials.

Sec. 552.223-72  Hazardous Material Information.

Sec. 552.225-70  Notice of Procurement Restriction--Hand or Measuring 
          Tools or Stainless Steel Flatware.

Sec. 552.227-70  Government Rights (Unlimited).

Sec. 552.227-71  Drawings and Other Data to Become Property of 
          Government.

Sec. 552.228-70  Workers' Compensation Laws.

Sec. 552.229-70  Federal, State, and Local Taxes.

Sec. 552.229-71  Federal Excise Tax--DC Government.

Sec. 552.232-1  Payments.

Sec. 552.232-8  Discounts for Prompt Payment.

Sec. 552.232-23  Assignment of Claims.

Sec. 552.232-25  Prompt Payment.

Sec. 552.232-70  Invoice Requirements.

Sec. 552.232-71  Adjusting Payments.

Sec. 552.232-72  Final Payment.

Sec. 552.232-73  Availability of Funds.

Sec. 552.232-74  Invoice Payments.

Sec. 552.232-75  Prompt Payment.

Sec. 552.232-76  Electronic Funds Transfer Payment.

Sec. 552.232-77  Payment By Governmentwide Commercial Purchase Card.

[[Page 212]]


Sec. 552.232-78  Payment Information.

Sec. 552.233-70  Protests Filed Directly with the General Services 
          Administration.

Sec. 552.236-70  Definitions.

Sec. 552.236-71  Authorities and Limitations.

Sec. 552.236-72  Specialist.

Sec. 552.236-73  Basis of Award--Construction Contract.

Sec. 552.236-74  Working Hours.

Sec. 552.236-75  Use of Premises.

Sec. 552.236-76  Measurements.

Sec. 552.236-77  Specifications and Drawings.

Sec. 552.236-78  Shop Drawings, Coordination Drawings, and Schedules.

Sec. 552.236-79  Samples.

Sec. 552.236-80  Heat.

Sec. 552.236-81  Use of Equipment by the Government.

Sec. 552.236-82  Subcontracts.

Sec. 552.236-83  Requirement for a Project Labor Agreement.

Sec. 552.237-70  Qualifications of Offerors.

Sec. 552.237-71  Qualifications of Employees.

Sec. 552.237-72  Prohibition Regarding ``Quasi-Military Armed Forces.''

Sec. 552.237-73  Restriction on Disclosure of Information.

Sec. 552.238-70  Identification of Electronic Office Equipment Providing 
          Accessibility for the Handicapped.

Sec. 552.238-71  Submission and Distribution of Authorized FSS Schedule 
          Pricelists.

Sec. 552.238-72  Identification of Energy-Efficient Office Equipment and 
          Supplies Containing Recovered Materials or Other Environmental 
          Attributes.

Sec. 552.238-73  Cancellation.

Sec. 552.238-74  Contractor's Report of Sales.

Sec. 552.238-75  Price Reductions.

Sec. 552.238-76  Industrial Funding Fee.

Sec. 552.242-70  Status Report of Orders and Shipments.

Sec. 552.243-70  Pricing of Adjustments.

Sec. 552.243-71  Equitable Adjustments.

Sec. 552.243-72  Modifications (Multiple Award Schedule).

Sec. 552.246-17  Warranty of Supplies of a Noncomplex Nature.

Sec. 552.246-70  Source Inspection by Quality Approved Manufacturer.

Sec. 552.246-71  Source Inspection by Government.

Sec. 552.246-72  Final Inspection and Tests.

Sec. 552.246-73  Warranty--Multiple Award Schedule.

Sec. 552.246-74  [Reserved]

Sec. 552.246-75  Guarantees.

Sec. 552.246-76  Warranty of Pesticides.

Sec. 552.247-70  Placarding Railcar Shipments.

Sec. 552.247-71  Diversion of Shipment Under F.O.B. Destination 
          Contracts.

Sec. 552.249-70  Termination for Convenience of the Government (Fixed 
          Price) (Short Form).

Sec. 552.249-71  Submission of Termination Liability Schedule.

Sec. 552.252-5  Authorized Deviations in Provisions.

Sec. 552.252-6  Authorized Deviations in Clauses.

Sec. 552.270-1  Instructions to Offerors--Acquisition of Leasehold 
          Interests in Real Property.

Sec. 552.270-2  Historic Preference.

Sec. 552.270-3  Parties to Execute Lease.

Sec. 552.270-4  Definitions.

Sec. 552.270-5  Subletting and Assignment.

Sec. 552.270-6  Maintenance of Building and Premises--Right of Entry.

Sec. 552.270-7  Fire and Casualty Damage.

Sec. 552.270-8  Compliance with Applicable Law.

Sec. 552.270-9  Inspection--Right of Entry.

Sec. 552.270-10  Failure in Performance.

Sec. 552.270-11  Successors Bound.

Sec. 552.270-12  Alterations.

Sec. 552.270-13  Proposals for Adjustment.

Sec. 552.270-14  Changes.

Sec. 552.270-15  Liquidated Damages.

Sec. 552.270-16  Adjustment for Vacant Premises.

Sec. 552.270-17  Delivery and Condition.

Sec. 552.270-18  Default in Delivery--Time Extensions.

Sec. 552.270-19  Progressive Occupancy.

Sec. 552.270-20  Payment.

Sec. 552.270-21  Effect of Acceptance and Occupancy.

Sec. 552.270-22  Default by Lessor During the Term.

Sec. 552.270-23  Subordination, Nondisturbance and Attornment.

Sec. 552.270-24  Statement of Lease.

Sec. 552.270-25  Substitution of Tenant Agency.

Sec. 552.270-26  No Waiver.

Sec. 552.270-27  Integrated Agreement.

Sec. 552.270-28  Mutuality of Obligation.

Sec. 552.270-29  Acceptance of Space.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37229, July 9, 1999, unless otherwise noted.



Sec. 552.000  Scope of part.

    This part provides the text of provisions and clauses which are 
unique to GSA or supplement the FAR.

       Subpart 552.1_Instructions for Using Provisions and Clauses



Sec. 552.101-70  Using part 552.

    (a) Definition. ``Clause,'' as used in this subpart, means provision 
or clause as defined in FAR 52.101(a).
    (b) Numbering. (1) Clauses which are ``substantially'' the same as 
FAR clauses and clauses to be used instead of FAR clauses are identified 
as follows:
    (i) The clause has the same title as a clause in the FAR.
    (ii) The number 5 precedes the clause.

[[Page 213]]

    (iii) The clause appears under the same subsection number and 
caption as in the FAR.
    (2) Supplemental clauses are numbered in the same manner as the FAR, 
except:
    (i) The chapter number precedes the clause.
    (ii) The subsection numbers begin with 70.
    (iii) The clauses are sequentially numbered, e.g., 552.232-70, 
552.232-71, etc.



Sec. 552.102  Incorporating provisions and clauses.

    You may incorporate clauses prescribed in the GSAR for solicitations 
and contracts by reference.



Sec. 552.103  Identification of provisions and clauses.

    Deviations. If the GSAR prescribes a class deviation from a FAR 
clause, identify the clause by the GSAR citation (e.g., 552.232-8 PROMPT 
PAYMENT DISCOUNT (NOV 1987) (DEVIATION FAR 552.232-8)).



Sec. 552.104  Procedures for modifying and completing provisions and 
          clauses.

    (a) The procedures in FAR 52.104 apply when you modify or complete a 
GSAR provision or clause. Provisions and clauses shall not be modified 
unless the GSAR authorizes their modification.
    (b) You do not need to identify modifications of clauses which 
result from negotiations unless you issue an amendment to the 
solicitation.
    (c) In general, you should modify FAR or GSAR clauses only for 
individual cases. If a contracting activity develops a modification for 
repeated use, furnish a copy to the Office of GSA Acquisition Policy 
(MV) for potential inclusion in the GSAR.



Sec. 552.105  Procedures for using alternates.

    The procedures in FAR 52.105 apply to GSAR part 552.



Sec. 552.107-70  Provisions and clauses prescribed in subpart 552.1.

    (a) Insert the provision at 552.252-5, Authorized Deviations in 
Provisions, in solicitation that include any FAR or GSAR clause with an 
authorized deviation. You must use this provision in lieu of the FAR 
provision at 552.252-5.
    (b) Insert the clause at 552.252-6, Authorized Deviations in 
Clauses, in solicitations and contracts that include any FAR or GSAR 
clause with an authorized deviation. You must use this clause in lieu of 
the FAR clause at 52.252-6.

              Subpart 552.2_Text of Provisions and Clauses



Sec. 552.200  Scope of subpart.

    This subpart sets forth the text of all GSAR provisions and clauses. 
It also cross-references the location in the GSAR that prescribes the 
use of each provision and clause.



Sec. 552.203-5  Covenant Against Contingent Fees.

    As prescribed in 502.404, insert the following clause:

              Convenant Against Contingent Fees (FEB 1990)

    (a) The Contractor warrants that no person or agency has been 
employed or retained to solicit or obtain this contract upon an 
agreement or understanding for a contingent fee, except a bona fide 
employee or agency. For breach or violation of this warrant, the 
Government shall have the right to annul this contract without liability 
or, in its discretion, to deduct from the contract price or 
consideration, or otherwise recover the full amount of the contingent 
fee.
    (b) ``Bona fide agency,'' as used in this clause, means an 
established commercial or selling agency (including licensed real estate 
agents or brokers), maintained by a Contractor for the purpose of 
securing business, that neither exerts nor proposes to exert improper 
influence to solicit or obtain Government contracts nor holds itself out 
as being able to obtain any Government contract or contracts through 
improper influence.
    ``Bona fide employee,'' as used in this clause, means a person, 
employed by a Contractor and subject to the Contractor's supervision and 
control as to time, place, and manner of performance, who neither exerts 
nor proposes to exert improper influence to solicit or obtain Government 
contracts nor holds out as being able to obtain any Government contract 
or contracts through improper influence.
    ``Contingent fee,'' as used in this clause, means any commission, 
percentage, brokerage, or other fee that is contingent upon the

[[Page 214]]

success that a person or concern has in securing a Government contract.
    ``Improper influence,'' as used in this clause, means any influence 
that induces or tends to induce a Government employee or officer to give 
consideration or to act regarding a Government contract on any basis 
other than the merits of the matter.

                             (End of clause)



Sec. 552.203-70  Price Adjustment for Illegal or Improper Activity.

    As prescribed in 503.104-9, insert the following clause:

      Price Adjustment for Illegal or Improper Activity (SEP 1999)

    (a) If the head of the contracting activity (HCA) or his or her 
designee determines that there was a violation of subsection 27(a) of 
the Office of Federal Procurement Policy Act, as amended (41 U.S.C. 
423), as implemented in the Federal Acquisition Regulation, the 
Government, at its election, may--
    (1) Reduce the monthly rental under this lease by 5 percent of the 
amount of the rental for each month of the remaining term of the lease, 
including any option periods, and recover 5 percent of the rental 
already paid;
    (2) Reduce payments for alterations not included in monthly rental 
payments by 5 percent of the amount of the alterations agreement; or
    (3) Reduce the payments for violations by a Lessor's subcontractor 
by an amount not to exceed the amount of profit or fee reflected in the 
subcontract at the time the subcontract was placed.
    (b) Prior to making a determination as set forth above, the HCA or 
designee shall provide to the Lessor a written notice of the action 
being considered and the basis therefor. The Lessor shall have a period 
determined by the agency head or designee, but not less than 30 calendar 
days after receipt of such notice, to submit in person, in writing, or 
through a representative, information and argument in opposition to the 
proposed reduction. The agency head or designee may, upon good cause 
shown, determine to deduct less than the above amounts from payments.
    (c) The rights and remedies of the Government specified herein are 
not exclusive, and are in addition to any other rights and remedies 
provided by law or under this lease.

                             (End of clause)



Sec. 552.203-71  Restriction on Advertising.

    As prescribed in 503.570-2, insert the following clause:

                  Restriction on Advertising (SEP 1999)

    The Contractor shall not refer to this contract in commercial 
advertising or similar promotions in such a manner as to state or imply 
that the product or service provided is endorsed or preferred by the 
White House, the Executive Office of the President, or any other element 
of the Federal Government, or is considered by these entities to be 
superior to other products or services. Any advertisement by the 
Contractor, including price-off coupons, that refers to a military 
resale activity shall contain the following statement: ``This 
advertisement is neither paid for nor sponsored, in whole or in part, by 
any element of the United States Government.''

                             (End of clause)



Sec. 552.209-70  Product Removal from Qualified Products List.

    As prescribed in 509.206-2, insert the following clause:

         Product Removal From Qualified Products List (SEP 1999)

    If, during the performance of this contract, the product being 
furnished is for any reason (except those outlined in paragraph 3.1.1 of 
the applicable Federal or Interim Federal Specification for security 
cabinets, security vault doors and changeable combination padlocks) 
removed from the Qualified Products List, the Government may terminate 
this contract for default.

                             (End of clause)



Sec. 552.209-71  Waiver of First Article Testing and Approval 
          Requirement.

    As prescribed in 509.306, insert the following provision:

   Waiver of First Article Testing and Approval Requirement (SEP 1999)

    (a) Offerors must submit an offer including testing and approval, 
however, an offeror may submit an alternate offer excluding testing and 
approval, provided the offeror satisfies the requirements for the 
waiving of first article testing.
    (b) Before a waiver of the first article testing requirement of this 
solicitation will be considered, the offeror is requested to identify 
the procurement under which the product offered was previously approved 
and accepted:

_______________________________________________________________________
(Offeror to insert both contract number and applicable national stock 
number.)

[[Page 215]]

                           (End of provision)



Sec. 552.209-72  Supplemental Requirements for First Article Approval--
          Contractor Testing.

    As prescribed in 509.308-1, insert the following clause:

Supplemental Requirements for First Article Approval--Contractor Testing 
                               (SEP 1999)

    (a) The term ``Contracting Officer'' as used in FAR 52.209-3, First 
Article Approval--Contractor Testing, means the Administrative 
Contracting Officer (ACO).
    (b) The Contractor shall have either (1) the necessary inspection 
and test equipment at the Contractor's plant to perform first article 
testing, or (2) if the inspection and test equipment is not available, a 
letter of commitment from a laboratory acceptable to the Government to 
perform the inspection and testing.
    (c) When the Government elects to witness the first article testing, 
the Contractor shall conduct the testing between the hours of 7:00 AM 
and 5:00 PM, Monday thru Friday, unless a different time is agreed to by 
the ACO.
    (d) The first article test report shall contain:
    (1) The complete test data, the test method(s) used and date of 
test;
    (2) Signature and printed name of the individual who performed the 
inspection;
    (3) Applicable specification/CID and/or drawing numbers;
    (4) Name and type of test equipment used; and
    (5) All numerical values as a result of testing with each noted as 
to whether it passes or fails the contract test requirements.
    (e) The first article shall be retained by the Contractor as the 
manufacturing standard and will be kept in a secure area, under control 
of the Quality Assurance Specialist (QAS), to protest against possible 
changes or alterations for the life of the contract. If the first 
article sample is destroyed during testing or damaged to a point making 
it unusable as a standard, the Contractor, upon Government request, 
shall provide a second sample.
    (f) If the Contractor delivers the approved first article as part of 
the contract quantity, it shall be in the last scheduled delivery under 
the contract.

                             (End of clause)



Sec. 552.209-73  Supplemental Requirements for First Article Approval--
          Government Testing.

    As prescribed in 509.308-2, insert the following clause:

Supplemental Requirements for First Article Approval--Government Testing 
                               (SEP 1999)

    (a) The term ``Contracting Officer'' as used in FAR 52.209-4, First 
Article Approval--Government Testing, means the Administrative 
Contracting Officer (ACO).
    (b) The first article shall be retained by the Contractor as the 
manufacturing standard and will be kept in a secure area, under the 
control of the Quality Assurance Specialist (QAS) to protect against 
possible changes or alterations for the life of the contract. If the 
first article sample is destroyed during testing or damaged to a point 
making it unusable as a standard, the Contractor, upon Government 
request, shall provide a second sample.
    (c) If the Contractor deliver the approved first article as part of 
the contract quantity, it shall be in the last scheduled delivery under 
the contract.

                             (End of clause)



Sec. 552.211-8  Time of Delivery.

    As prescribed in 511.404(a)(1) insert the following clause:

                       Time of Delivery (SEP 1999)

    (a) The time of delivery for each item means the time required after 
receipt of an order (1) to make delivery to a destination in the case of 
delivered prices, or (2) to place shipment in transit in the case of 
f.o.b. origin prices.
    (b) Delivery is required to be made at the point(s) specified within 
___ days after receipt of order.

                             (End of clause)

    Alternate I (SEP 1999). It it is necessary to show different 
delivery times for different items or groups of items, the Contracting 
Officer may substitute the following paragraph (b) for paragraph (b) of 
the basis clause.

    (b) Delivery is required to be made at the point(s) specified within 
the number of calender days after receipt of order as indicated below:

------------------------------------------------------------------------
   Items or groups of items  (Special Item       Required delivery time
           Numbers or Nomenclature)                    (DAYS ARO)
------------------------------------------------------------------------
                                               .........................
                                               .........................
                                               .........................
------------------------------------------------------------------------


[[Page 216]]



Sec. 552.211-70  [Reserved]



Sec. 552.211-71  Standard References.

    As prescribed in 511.204(a), insert the following clause:

                     Standard References (SEP 1999)

    (a) All documents and publications (such as, but not limited to, 
manuals, handbooks, codes, standards and specifications) cited in this 
contract for the purpose of establishing requirements applicable to 
equipment, materials, or workmanship under this contract, shall be 
deemed to be incorporated herein as fully as if printed and bound with 
the specifications of this contract, in accordance with the following:
    (1) Wherever reference is made to Standard Specifications of the 
Public Buildings Service, Interim Federal Specifications, Interim 
Amendments to Federal Specifications, Interim Federal Standards, or 
Interim Amendments to Federal Standards, the Contractor shall comply 
with the requirements set out in the issue or edition identified in this 
contract.
    (2) Wherever reference is made to any such document other than those 
specified in subparagraph (1) above, the Contractor shall comply with 
the requirements set out in the edition specified in this contract, or 
if not specified, the latest edition or revision thereof, as well as the 
latest amendment or supplement thereto, in effect on the date of the 
solicitation on this project, except as modified by, as otherwise 
provided in, or as limited to type, class or grade, by the 
specifications of this contract.
    (b) Upon request the Contractor shall make available at the job site 
within a reasonable time, a copy of each trade manual and standard which 
is incorporated by reference in this contract and which governs quality 
and workmanship.

                             (End of clause)



Sec. 552.211-72  Reference to Specifications in Drawings.

    As prescribed in 511.204(b), insert the following clause:

           References to Specifications in Drawings (FEB 1996)

    If military or other drawings are made a part of this contract, any 
reference in the drawings to Federal specifications or standards will be 
considered to be a reference to the date of such Federal specification 
or standard identified in the contract. If the date of the Federal 
specification or standard is not identified in the contract, the 
edition, including revisions thereto, in effect on the date the 
solicitation is issued will apply.

                             (End of clause)



Sec. 552.211-73  Marking.

    As prescribed in 511.204(c)(1), insert the following clause:

                           Marking (FEB 1996)

    (a) General requirements. Interior packages, if any, and exterior 
shipping containers shall be marked as specified elsewhere in the 
contract. Additional marking requirements may be specified on delivery 
orders issued under the contract. If not otherwise specified, interior 
packages and exterior shipping containers shall be marked in accordance 
with the following standards:
    (1) Deliveries to civilian activities. Supplies shall be marked in 
accordance with Federal Standard 123, edition in effect on the date of 
issuance of the solicitation.
    (2) Deliveries to military activities. Supplies shall be marked in 
accordance with Military Standard 129, edition in effect on the date of 
issuance of the solicitation.
    (b) Improperly marked material. When Government inspection and 
acceptance are at destination, and delivered supplies are not marked in 
accordance with contract requirements, the Government has the right, 
without prior notice to the Contractor, to perform the required marking, 
by contract or otherwise, and charge the Contractor therefor at the rate 
specified elsewhere in this contract. This right is not exclusive, and 
is in addition to other rights or remedies provided for in this 
contract.

                             (End of clause)



Sec. 552.211-74  Charges for Marking.

    As prescribed in 511.204(c)(2), insert a clause substantially as 
follows:

                     Charges for Marking (FEB 1996)

    The rate provided for in paragraph (b) of 552.211-73, Marking, is 
$____* per man-hour or fraction thereof.

                             (End of clause)

    * The rate to be inserted in the above clause shall be determined 
and published by the Commissioner, Federal Supply Service, or a 
designee.



Sec. 552.211-75  Preservation, Packaging and Packing.

    As prescribed in 511.204(c)(3), insert the following clause:

[[Page 217]]

             Preservation, Packaging, and Packing (FEB 1996)

    Unless otherwise specified, all items shall be preserved, packaged, 
and packed in accordance with normal commercial practices, as defined in 
the applicable commodity specification. Packaging and packing shall 
comply with the requirements of the Uniform Freight Classification and 
the National Motor Freight Classification (issue in effect at time of 
shipment) and each shipping container of each item in a shipment shall 
be of uniform size and content, except for residual quantities. Where 
special or unusual packing is specified in an order, but not 
specifically provided for by the contract, such packing details must be 
the subject of an agreement independently arrived at between the 
ordering agency and the Contractor.

                             (End of clause)



Sec. 552.211-76  Charges for Packaging and Packing.

    As prescribed in 511.204(c)(4), insert a clause substantially as 
follows:

              Charges for Packaging and Packing (FEB 1996)

    If supplies shipped to a GSA wholesale distribution center are not 
packaged and packed in accordance with contract requirements, the 
Government has the right, without prior notice to the Contractor, to 
perform the required repackaging/repacking, by contract or otherwise, 
and charge the Contractor therefore at the rate of $__*__ per man-hour 
or fraction thereof. The Contractor will also be charged for material 
costs, if incurred. This right is not exclusive, and is in addition to 
other rights or remedies provided for in this contract.

                             (End of clause)

    * The rate to be inserted in the above clause shall be determined by 
the Commissioner, Federal Supply Service, or a designee.



Sec. 552.211-77  Packing List.

    As prescribed in 511.204(d), insert the following clause:

                         Packing List (FEB 1996)

    (a) A packing list or other suitable shipping document shall 
accompany each shipment and shall indicate:
    (1) Name and address of the consignor;
    (2) Name and complete address of the consignee;
    (3) Government order or requisition number;
    (4) Government bill of lading number covering the shipment (if any); 
and
    (5) Description of the material shipped, including item number, 
quantity, number of containers, and package number (if any).
    (b) When payment will be made by Government commercial credit card, 
in addition to the information in (a) above, the packing list or 
shipping document shall include:
    (1) Cardholder name and telephone number and
    (2) The term ``Credit Card.''

                             (End of clause)



Sec. 552.211-78  Commercial Delivery Schedule (Multiple Award Schedule).

    As prescribed in 511.404(a)(2), insert the following clause:

    Commercial Delivery Schedule (Multiple Award Schedule) (FEB 1996)

    (a) Time of Delivery. The Contractor shall deliver to destination 
within the number of calendar days after receipt of order (ARO) in the 
case of F.O.B. Destination prices, or to place of shipment in transit in 
the case of F.O.B. Origin prices, as set forth below. Offerors shall 
insert in the ``Time of Delivery (days ARO)'' column in the schedule of 
Items a definite number of calendar days within which delivery will be 
made. In no case shall the offered delivery time exceed the Contractor's 
normal commercial practice. The Government requires the Contractor's 
normal commercial delivery time, as long as it is less than the 
``STATED'' delivery time(s) shown below. If the Offeror does not insert 
a delivery time in the schedule of items, the Offeror will be deemed to 
offer delivery in accordance with the Government's stated delivery time 
as stated below:

------------------------------------------------------------------------
                                              Government's  Contractor's
                                                 stated        normal
   Items or group of items  (Special Item       delivery     commercial
           Number or Nomenclature)             time  (days    delivery
                                                  ARO)          time
------------------------------------------------------------------------
                                              ............  ............
                                              ............  ............
                                              ............  ............
------------------------------------------------------------------------

    (b) Expedited Delivery Times. For those items that can be delivered 
quicker than the delivery times in paragraph (a), above, the Offeror is 
requested to insert below, a time (hours/days ARO) that delivery can be 
made when expedited delivery is requested.

------------------------------------------------------------------------
                                                              Expedited
                                                               delivery
      Item or group of items  (Special Item Number or            time
                       Nomenclature)                         (HOURS/DAYS
                                                                 ARO)
------------------------------------------------------------------------
                                                             ...........
                                                             ...........

[[Page 218]]

 
                                                             ...........
------------------------------------------------------------------------

    (c) Overnight and 2-Day Delivery Times. Ordering activities may 
require overnight or 2-day delivery. The Offeror is requested to 
annotate its price list or by separate attachment identify the items 
that can be delivered overnight or within 2 days. Contractors offering 
such delivery services will be required to state in the cover sheet to 
its FSS price list details concerning this service.

                             (End of clause)



Sec. 552.211-79  Acceptable Age of Supplies.

    As prescribed in 511.404(a)(3)(i), insert the following clause:

                  Acceptable Age of Supplies (FEB 1996)

    The supplies furnished under this contract shall not be more than __ 
months old, beginning with the first full month after the date of 
manufacture marked on the container. For the purpose of this clause, 
supplies shall be considered to be furnished (1) when they are offered 
to the Government for inspection and testing, or (2) on the date of 
shipment if shipment is authorized to be made without prior inspection 
by the Government. If the age of the supplies furnished under this 
contract is greater than the specified period, the Government may 
exercise its right to reject the supplies.

                             (End of clause)

    Alternate I (FEB 1996). For items having a limited shelf-life, the 
sentence below should be substituted for the first sentence of the basic 
clause when authorized:

    The supplies furnished under this contract shall not be more than __ 
days old, beginning with the date of manufacture (month, day, year) 
marked on the container.



Sec. 552.211-80  Age on Delivery.

    As prescribed in 511.404(a)(3)(ii) insert the following clause:

                       Age on Delivery (FEB 1996)

    Included in the description of each shelf-life item is a statement 
regarding the ``age on delivery.'' The age of the item(s) shall not 
exceed the number of months shown in the item description, counted from 
the first day of the month after the month of manufacture to the date of 
delivery to the specified delivery point(s). If the age of the supplies 
delivered under this contract is greater than the number of months 
shown, the Government may exercise its right to reject the supplies.

                             (End of clause)



Sec. 552.211-81  Time of Shipment.

    As prescribed in 511.404(a)(4), insert the following clause:

                       Time of Shipment (FEB 1996)

    Shipment is required within ___ calendar days after receipt of 
order.

                             (End of clause)

    Alternate I (FEB 1996). If the contract will require shipment more 
than 45 calendar days after receipt of the order, the following 
paragraph should be added to the basic clause.
    Each delivery order will specify that shipment is required no later 
than the number of days shown above. If such order also states that 
``Early Shipment is Precluded,'' the Contractor agrees to make shipment 
no sooner than ___ calendar days after receipt of order. Earlier 
shipments may result in nonacceptance of the supplies at the delivery 
point at the time of arrival.

    (The second number to be inserted should be 15 calendar days less 
than the first number.)



Sec. 552.211-82  Notice of Shipment.

    As prescribed in 511.404(a)(5), insert the following clause:

                      Notice of Shipment (FEB 1996)

    If specified in an order placed under this contract, the Contractor 
shall, at the time each shipment is made on such order, furnish a notice 
of shipment to either the consignee or the ordering office or both, as 
specified. This requirement may be satisfied by completion and return of 
appropriate forms furnished by the ordering office or by the furnishing 
of copies of bills of lading, freight bills, or similar documents in 
accordance with normal commercial practice if such document clearly 
identifies the order number, items and quantities shipped, date of 
shipment, point of origin, method of shipment and routing, and the name 
of initial carrier.

                             (End of clause)



Sec. 552.211-83  Availability for Inspection, Testing, and Shipment/
          Delivery.

    As prescribed in 511.404(a)(6), insert the following clause:

[[Page 219]]

 Availability for Inspection, Testing, and Shipment/Delivery (FEB 1996)

    (a) The Government requires that the supplies be made available for 
inspection and testing within ____*____ calendar days after receipt of 
[Insert ``Notice of Award'' or ``order''], and be [Insert ``shipped'' or 
``delivered''] within ____*____ calendar days after receipt of (1) 
notice of approval and release by the Government inspector or (2) 
authorization to ship without Government inspection.
    (b) Failure to make supplies available for inspection and testing or 
to [Insert ``ship'' or ``deliver''] as required by this clause may 
result in termination of this contract for default.

                             (End of clause)

    Alternate I (FEB 1996). If the contract is for stock items, the 
Contracting Officer shall insert ``shipped'' or ``ship'' in the basic 
clause, add the following paragraph (b) and redesignate paragraph (b) of 
the basic clause as paragraph (c).

    (b) If notice of approval and release by the Government inspector or 
authorization to ship without Government inspection is received before 
____*____ calendar days after receipt of the [Insert ``Notice of Award'' 
or ``order''], receipt of such notice shall be deemed to be received on 
the ____*____ calendar day after receipt of [Insert ``Notice of Award'' 
or ``order'']. Shipments shall not be made before the ____*____ calendar 
day after receipt of the [Insert ``Notice of Award'' or ``order''] 
unless authorized in writing by the Contracting Officer.
    * Entries are normally the same number of days specified for 
availability.



Sec. 552.211-84  Non-Compliance With Contract Requirements.

    As prescribed in 511.404(b), insert the following clause:

          Non-Compliance With Contract Requirements (FEB 1996)

    In the event the Contractor, after receiving written notice from the 
Contracting Officer of non-compliance with any requirement of this 
contract, fails to initiate promptly such action as may be appropriate 
to comply with the specified requirement within a reasonable period of 
time, the Contracting Officer shall have the right to order the 
Contractor to stop any or all work under the contract until the 
Contractor has complied or has initiated such action as may be 
appropriate to comply within a reasonable period of time. The Contractor 
will not be entitled to any extension of contract time or payment for 
any costs incurred as a result of being ordered to stop work for such 
cause.

                             (End of clause)



Sec. 552.212-70  Preparation of Offer (Multiple Award Schedule).

    As prescribed in 512.301(a)(1), insert the following clause:

        Preparation of Offer (Multiple Award Schedule) (AUG 1997)

    (a) Definitions. Concession, as used in this solicitation, means a 
benefit, enhancement or privilege (other than a discount), which either 
reduces the overall cost of a customer's acquisition or encourages a 
customer to consummate a purchase. Concessions include, but are not 
limited to freight allowance, extended warranty, extended price 
guarantees, free installation and bonus goods.
    Discount, as used in this solicitation, means a reduction to catalog 
prices (published or unpublished). Discounts include, but are not 
limited to, rebates, quantity discounts, purchase option credits, and 
any other terms or conditions other than concessions) which reduce the 
amount of money a customer ultimately pays for goods or services ordered 
or received. Any net price lower than the list price is considered a 
``discount'' by the percentage difference from the list price to the net 
price.
    (b) For each Special Item Number (SIN) included in an offer, the 
Offeror shall provide the information outlined in paragraph (c). 
Offerors may provide a single response covering more than one SIN, if 
the information disclosed is the same for all products under each SIN. 
If discounts and concessions vary by model or product line, offerors 
shall ensure that information is clearly annotated as to item or items 
referenced.
    (c) Provide information described below for each SIN:
    (1) Two copies of the offeror's current published (dated or 
otherwise identified) commercial descriptive catalogs and/or price 
list(s) from which discounts are offered. If special catalogs or price 
lists are printed for the purpose of this offer, such descriptive 
catalogs or price lists shall include a statement indicating the special 
catalog or price list represent a verbatim extract from the Offeror's 
commercial catalog and/or price list and identify the descriptive 
catalog and/or price list from which the information has been extracted.
    (2) Next to each offered item in the commercial catalog and/or price 
list, the Offeror shall write the special item number (SIN) under which 
the item is being offered. Unless a special catalog or price list is 
submitted,

[[Page 220]]

all other items shall be marked ``excluded,'' lined out, and initiated 
by the offeror.
    (3) The discount(s) offered under this solicitation. The description 
of discounts offered shall include all discounts, such as prompt payment 
discounts, quantity/dollar volume discounts (indicate whether models/
products can be combined within the SIN or whether SINs can be combined 
to earn discounts), blanket purchase agreement discounts, or purchase 
option credits. If the terms of sale appearing in the commercial 
catalogs or price list on which an offer is based are in conflict with 
the terms of this solicitation, the latter shall govern.
    (4) A description of concessions offered under this solicitation 
which are not granted to other customers. Such concessions may include, 
but are not limited to, an extended warranty, a return/exchange goods 
policy, or enhanced or additional services.
    (5) If the Offeror is a dealer/reseller or the Offeror will use 
dealers to perform any aspect of contract awarded under this 
solicitation, describe the functions, if any, that the dealer/reseller 
will perform.

                             (End of clause)



Sec. 552.212-71  Contract Terms and Conditions Applicable to GSA 
          Acquisition of Commercial Items.

    As prescribed in 512.301(a)(2), insert the following clause:

     Contract Terms and Conditions Applicable to GSA Acquisition of 
                       Commercial Items (JUL 2000)

    The Contractor agrees to comply with any provision or clause that is 
incorporated herein by reference to implement agency policy applicable 
to acquisition of commercial items or components. The provision or 
clause in effect based on the applicable regulation cited on the date 
the solicitation is issued applies unless otherwise stated herein. The 
following provisions and clauses are incorporated by reference:

[The contracting officer should either check the provisions and clauses 
that apply or delete the provisions and clauses that do not apply from 
the list. The contracting officer may add the date of the provision or 
clause if desired for clarity.]
    (a) Provisions.

__ 552.237-70  Qualifications of Offerors

    (b) Clauses.

__ 552.203-71  Restriction on Advertising
__ 552.211-73  Marking
__ 552.2215-70  Examination of Records by GSA
__ 552.215-71  Examination of Records by GSA (Multiple Award Schedule)
__ 552.215-72  Price Adjustment--Failure to Provide Accurate Information
__ 552.219-70  Allocation of Orders--Partially Set-Aside Items
__ 552.228-70  Workers' Compensation Laws
__ 552.229-70  Federal, State, and Local Taxes
__ 552.232-8  Discounts for Prompt Payment
__ 552.232-23  Assignment of Claims
__ 552.232-71  Adjusting Payments
__ 552.232-72  Final Payment
__ 552.232-73  Availability of Funds
__ 552.232-78  Payment Information
__ 552.237-71  Qualifications of Employees
__ 552.238-71  Submission and Distribution of Authorized FSS Schedule 
Price List
__ 552.238-74  Contractor's Report of Sales
__ 552.238-75  Price Reductions
__ 552.242-70  Status Report of Orders and Shipments
__ 552.243-72  Modifications  (Multiple Award Schedule)
__ 552.246-73  Warranty--Multiple  Award Schedule
__ 552.246-76  Warranty of Pesticides

                             (End of clause)

[64 FR 37229, July 9, 1999, as amended at 65 FR 41379, July 5, 2000]



Sec. 552.212-72  Contract Terms and Conditions Required To Implement 
          Statutes or Executive Orders Applicable to GSA Acquisition of 
          Commercial Items.

    As prescribed in 512.301(a)(3), insert the following clause:

    Contract Terms and Conditions Required To Implement Statutes or 
Executive Orders Applicable to GSA Acquisition of Commercial Items (JUL 
                                  2000)

    The Contractor agrees to comply with any provision or clause that is 
incorporated herein by reference to implement provisions of law or 
Executive Orders applicable to acquisition of commercial items or 
components. The provision or clause in effect based on the applicable 
regulation cited on the date the solicitation is issued applies unless 
otherwise stated herein. The following provisions and clauses are 
incorporated by reference:

[The contracting officer should either check the provisions and clauses 
that apply or delete the provisions and clauses that do not apply from 
the list. The contracting officer may add the date of the provision or 
clause if desired for clarity.]
    (a) Provisions.

__ 552.223-72  Hazardous Material Information

    (b) Clauses.

__ 552.223-70  Hazardous Substances
__ 552.223-71  Nonconforming Hazardous Material

[[Page 221]]

__ 552.238-70  Identification of Electronic Office Equipment Providing 
Accessibility for the Handicapped
__ 552.238-72  Identification of Energy-Efficient Office Equipment and 
Supplies Containing Recovered Materials or Other Environmental 
Attributes
__ 552.238-76  Industrial Funding Fee

                             (End of clause)

[64 FR 37229, July 9, 1999, as amended at 65 FR 41379, July 5, 2000]



Sec. 552.212-73  Evaluation--Commercial Items (Multiple Award Schedule).

    As prescribed in 512.301(a)(4), insert the following provision:

    Evaluation--Commercial Items (Multiple Award Schedule) (AUG 1997)

    (a) The Government may make multiple awards for the supplies or 
services offered in response to this solicitation that meet the 
definition of a ``commercial item'' in FAR 52.202-1. Awards may be made 
to those responsible offerors that offer reasonable pricing, conforming 
to the solicitation, and will be most advantageous to the Government, 
taking into consideration the multiplicity and complexity of items of 
various manufacturers and the differences in performance required to 
accomplish or produce required end results, production and distribution 
facilities, price, compliance with delivery requirements, and other 
pertinent factors. By providing a selection of comparable supplies or 
services, ordering activities are afforded the opportunity to fulfill 
their requirements with the item(s) that constitute the best value and 
that meet their needs at the lowest overall cost.
    (b) A written notice of award or acceptance of an offer, mailed or 
otherwise furnished to the offeror within the time for acceptance 
specified in the offer, shall result in a binding contract without 
further action by either party. Before the offer's specified expiration 
time, the Government may accept an offer (or part of an offer), whether 
or not there are negotiations after its receipt, unless a written notice 
of withdrawal is received before award.

                           (End of provision)

    Alternate I (AUG 1997). When anticipating competition of identical 
items, add the following paragraph after paragraph (b) of the basic 
provision.

    (c) The Government reserves the right to award only one contract for 
all or a part of a manufacturer's product line. When two or more 
offerors (e.g., dealers/resellers) offer the identical product, award 
may be made competitively to only one offeror on the basis of the lowest 
price. (Discounts for early payment will not be considered as an 
evaluation factor in determining the low offeror). During initial open 
season for an option period, any offers that are equal to or lower than 
the current contract price received for identical items will be 
considered. Current contractors will also be allowed to submit offers 
for identical items during this initial open season. The current 
contractor which has the identical item on contract will be included in 
the evaluation process. The Government will evaluate all offers and may 
award only one contract for each specified product or aggregate group.



Sec. 552.214-70  ``All or None'' Offers.

    As prescribed in 514.201-6, insert the following provision:

                    ``All or None'' Offers (SEP 1999)

    (a) Unless awards in the aggregate are specifically precluded in 
this solicitation, the Government reserves the right to evaluate offers 
and make awards on all ``all or none'' basis as provided below.
    (b) An offer submitted on an ``all or none'' or similar basis will 
be evaluated as follows: The lowest acceptable offer exclusive of the 
``all or none'' offer will be selected with respect to each item (or 
group of items when the solicitation provides for aggregate awards) and 
the total cost of all items thus determined shall be compared with the 
total of the lowest acceptable ``all or none'' offer. Award will be made 
to result in the lowest total cost to the Government.

                           (End of provision)

    Alternate I (SEP 1999). For a requirements or indefinite quantity 
contract, the following paragraph (b) shall be substituted in the basic 
provision:

    (b) An offer submitted on an ``all or none'' or similar basis will 
not be considered unless the offer is low on each item to which the 
``all or none'' offer is made applicable. The term ``each item'' as used 
in this provision refers either to an item that under the terms of the 
solicitation may be independently awarded, or to a group of items on 
which an award is to be made in the aggregate.



Sec. 552.214-71  Progressive Awards and Monthly Quantity Allocations.

    As prescribed in 514.201-7(a), insert the following clause:

     Progressive Awards and Monthly Quantity Allocations (SEP 1999)

    (a) Monthly quantity allocation.

[[Page 222]]

    (1) Set forth below are the Government's estimated annual and 
monthly requirements for each stock item covered by this solicitation. 
Offerors shall indicate, in the spaces provided, the monthly quantity 
which they are willing to furnish of any item or group of items 
involving the use of the same production facilities. In making monthly 
allocations, offerors are urged to group as many items as possible. Such 
groupings will make it possible for the Government to make fullest use 
of the production capabilities of each offeror.
    (2) Offerors need not limit their monthly allocations to the 
Government's estimated monthly requirements, since additional 
unanticipated needs may occur during the period of the contract. If an 
offeror does not insert monthly allocation quantities, it will be deemed 
to offer to furnish all of the Government's requirements, even though 
they may exceed the stated estimated requirements.

------------------------------------------------------------------------
                                   Estimated annual    Estimated monthly
     National stock number           requirements        requirements
------------------------------------------------------------------------
                                 ...................
                                 ...................
------------------------------------------------------------------------


                  Bidders Monthly Quantity Allocations
------------------------------------------------------------------------
                                                  Monthly allocation
          Items or groups of items                     quantity
------------------------------------------------------------------------
                                              ..........................
                                              ..........................
------------------------------------------------------------------------

    (b) Progressive awards. If the low responsive offeror's monthly 
quantity allocation is less than the Government's estimated 
requirements, the Government may make progressive awards beginning with 
the low responsive offeror and including each next low responsive 
offeror to the extent necessary to meet the estimated requirements.
    (c) Ordering procedures. If progressive awards are made, orders will 
be placed first with the Contractor offering the lowest price on each 
item normally up to that Contractor's maximum quantity allocation and 
then, in the same manner, successively to other Contractors. When 
cumulative orders during any month, placed with a lower priced 
Contractor, equal or exceed 95 percent of its monthly quantity 
allocation, to avoid the placement of unduly small orders or the 
splitting of a subsequent order, the Government reserves the right to 
award the full quantity of the subsequent order to the next lower priced 
Contractor. In no case will orders be placed with any Contractor in 
excess of its monthly quantity allocation.

                             (End of clause)



Sec. 552.214-72  Bid Sample Requirements.

    As prescribed in 514.202-4(a)(3), insert the following provision:

                   Bid Sample Requirements (SEP 1999)

    This provision supplements FAR 52.214-20, which is incorporated by 
reference. Samples shall be from the production of the manufacturer 
whose products will be supplied under resultant contracts.
    (a) Two bid samples are required for each of the following items in 
this solicitation:

_______________________________________________________________________
    (b) Two representative samples shall be submitted for each of the 
following items upon which a bid is submitted:

------------------------------------------------------------------------
                                            Acceptable representative
                 Items                               samples
------------------------------------------------------------------------
                                         ...............................
                                         ...............................
------------------------------------------------------------------------

    Note: (1) Bidders {time}  are or {time}  are not authorized to re-
apply samples being retained by GSA in connection with previous 
solicitations and/or resultant contracts. When the block ``are'' is 
marked by the government, FAR 52.214-20, Alternate II, shall apply.
    (2) Bidders who propose to furnish an item or group of items from 
more than one manufacturer or production point must submit two samples 
from the production of each manufacturer or production point.
    (c) Samples will be evaluated to determine compliance with all 
characteristics listed below:

------------------------------------------------------------------------
        Subjective characteristics            Objective characteristics
------------------------------------------------------------------------
                                            ............................
                                            ............................
------------------------------------------------------------------------

    (d) Forward samples addressed to the Sample Room indicated below. 
Except for samples delivered by U.S. Mail, deliveries will be accepted 
between the hours of __________ Mondays through Fridays, official 
holidays excluded.
    Caution: Use proper address for method of shipment selected.

Mail and Parcel Post
(Insert Address of Bid Sample Room)
Freight or Express
(Insert address of Bid Sample Room)

                           (End of provision)



Sec. 552.215-70  Examination of Records by GSA.

    As prescribed in 514.201-7(b) and 515.209-70(a) insert the following 
clause:

[[Page 223]]

                Examination of Records by GSA (FEB 1996)

    The Contractor agrees that the Administrator of General Services or 
any duly authorized representatives shall, until the expiration of 3 
years after final payment under this contract, or of the time periods 
for the particular records specified in Subpart 4.7 of the Federal 
Acquisition Regulation (48 CFR 4.7), whichever expires earlier, have 
access to and the right to examine any books, documents, papers, and 
records of the Contractor involving transactions related to this 
contract or compliance with any clauses thereunder. The Contractor 
further agrees to include in all its subcontracts hereunder a provision 
to the effect that the subcontractor agrees that the Administrator of 
General Services or any authorized representatives shall, until the 
expiration of 3 years after final payment under the subcontract, or of 
the time periods for the particular records specified in Subpart 4.7 of 
the Federal Acquisition Regulation (48 CFR 4.7), whichever expires 
earlier, have access to and the right to examine any books, documents, 
papers, and records of such subcontractor involving transactions related 
to the subcontract or compliance with any clauses thereunder. The term 
``subcontract'' as used in this clause excludes (a) purchase orders not 
exceeding $100,000 and (b) subcontracts or purchase orders for public 
utility services at rates established for uniform applicability to the 
general public.

                             (End of clause)



Sec. 552.215-71  Examination of Records by GSA (Multiple Award 
          Schedule).

    As prescribed in 515.209-70(c), insert the following clause:

   Examination of Records by GSA (Multiple Award Schedule) (AUG 1997)

    The Contractor agrees that the Administrator of General Services or 
any duly authorized representative shall have access to and the right to 
examine any books, documents, papers and records of the contractor 
involving transactions related to this contract for overbillings, 
billing errors, compliance with the Price Reduction clause and 
compliance with the Industrial Funding Fee clause of this contract. This 
authority shall expire 3 years after final payment. The basic contract 
and each option shall be treated as separate contracts for purposes of 
applying this clause.

                             (End of clause)



Sec. 552.215-72  Price Adjustment--Failure to Provide Accurate 
          Information.

    As prescribed in 515.408(d), insert the following clause:

  Price Adjustment--Failure To Provide Accurate Information (AUG 1997)

    (a) The Government, at its election, may reduce the price of this 
contract or contract modification if the Contracting Officer determines 
after award of this contract or contract modification that the price 
negotiated was increased by a significant amount because the Contractor 
failed to:
    (1) Provide information required by this solicitation/contract or 
otherwise requested by the Government; or
    (2) Submit information that was current, accurate, and complete; or
    (3) Disclose changes in the Contractor's commercial pricelist(s), 
discounts or discounting policies which occurred after the original 
submission and prior to the completion of negotiations.
    (b) The Government will consider information submitted to be 
current, accurate and complete if the data is current, accurate and 
complete as of 14 calendar days prior to the date it is submitted.
    (c) If any reduction in the contract price under this clause reduces 
the price for items for which payment was made prior to the date of the 
modification reflecting the price reduction, the Contractor shall be 
liable to and shall pay the United States--
    (1) The amount of the overpayment; and
    (2) Simple interest on the amount of such overpayment to be computed 
from the date(s) of overpayment to the Contractor to the date the 
Government is repaid by the Contractor at the applicable underpayment 
rate effective each quarter prescribed by the Secretary of Treasury 
under 26 U.S.C. 6621(a)(2).
    (d) Failure to agree on the amount of the decrease shall be resolved 
as a dispute.
    (e) In addition to the remedy in paragraph (a) of this clause, the 
Government may terminate this contract for default. The rights and 
remedies of the Government specified herein are not exclusive, and are 
in addition to any other rights and remedies provided by law or under 
this contract.


[[Page 224]]



                             (End of Clause)



Sec. 552.216-70  Economic Price Adjustment--FSS Multiple Award Schedule 
          Contracts.

    As prescribed in 516.203-4(a), insert the following clause:

 Economic Price Adjustment--FSS Multiple Award Schedule Contracts (SEP 
                                  1999)

    Price adjustments include price increases and price decreases. 
Adjustments will be considered as follows:
    (a) Contractors shall submit price decreases anytime during the 
contract period in which they occur. Price decreases will be handled in 
accordance with the provisions of the Price Reduction Clause.
    (b) Contractors may request price increases under the following 
conditions:
    (1) Increases resulting from a reissue or other modification of the 
Contractor's commercial catalog/pricelist that was used as the basis for 
the contract award.
    (2) Only three increases will be considered during the contract 
period.
    (3) Increases are requested after the first 30 days of the contract 
period and prior to the last 60 days of the contract period.
    (4) At least 30 days elapse between requested increases.
    (c) The aggregate of the increases in any contract unit price under 
this clause shall not exceed ___* percent of the original contract unit 
price. The Government reserves the right to raise this ceiling where 
changes in market conditions during the contract period support an 
increase.
    (d) The following material shall be submitted with the request for a 
price increase:
    (1) A copy of the commercial catalog/pricelist showing the price 
increase and the effective date for commercial customers.
    (2) Commercial Sales Practice format regarding the Contractor's 
commercial pricing practice relating to the reissued or modified 
catalog/price-list, or a certification that no change has occurred in 
the data since completion of the initial negotiation or a subsequent 
submission.
    (3) Documentation supporting the reasonableness of the price 
increase.
    (e) The Government reserves the right to exercise one of the 
following options:
    (1) Accept the Contractor's price increases as requested when all 
conditions of (b), (c), and (d) of this clause are satisfied;
    (2) Negotiate more favorable discounts from the new commercial 
prices when the total increase requested is not supported; or,
    (3) Remove the product(s) from contract involved pursuant to the 
Cancellation Clause of this contract, when the increase requested is not 
supported.
    (f) The contract modification reflecting the price adjustment shall 
be signed by the Government and made effective upon receipt of 
notification from the Contractor that the new catalog/pricelist has been 
mailed to the addresses previously furnished by the Contracting Officer, 
provided that in no event shall such price adjustment be effective prior 
to the effective date of the commercial price increases. The increased 
contract prices shall apply to delivery orders issued to the Contractor 
on or after the effective date of the contract modification.

                             (End of clause)

    * Insert the percent appropriate at the time the solicitation is 
issued. This percentage should normally be 10 percent, unless based on a 
trend established by an appropriate index such as the Producer Prices 
and Price Index during the most recent 6-month period indicates that a 
different percentage is more appropriate. Any ceiling other than 10 
percent must be approved by the contracting director.
    Alternate I (SEP 1999). The following is substituted for paragraphs 
(b) and (c) of the clause:

    (b) Contractors may request price increases to be effective on or 
after the first 12 months of the contract period providing all of the 
following conditions are met:
    (1) Increases resulting from a reissue or other modification of the 
Contractor's commercial catalog/pricelist that was used as the basis for 
the contract award.
    (2) No more than three increases will be considered during each 
succeeding 12-month period of the contract. (For succeeding contract 
periods of less than 12 months, up to three increases will be considered 
subject to the other conditions of this subparagraph (b)).
    (3) Increases are requested before the last 60 days of the contract 
period.
    (4) At least 30 days elapse between requested increases.
    (c) In any contract period during which price increases will be 
considered, the aggregate of the increases during any 12-month period 
shall not exceed *____ percent of the contract unit price in effect at 
the end of the preceding 12-month period. The Government reserves the 
right to raise the ceiling when market conditions during the contract 
period support such a change.
    * Insert the percentage appropriate at the time the solicitation is 
issued. This percentage should be determined based on the trend 
established by an appropriate index such as the Producer Prices and

[[Page 225]]

Price Index. A ceiling of more than 10 percent must be approved by the 
Contracting Director.

[64 FR 37229, July 9, 1999; 64 FR 49844, Sept. 14, 1999]



Sec. 552.216-71  Economic Price Adjustment--Stock and Special Order 
          Program Contracts.

    As prescribed in 516.203-4(b), insert the following clause:

Economic Price Adjustment-Stock and Special Order Program Contracts (SEP 
                                  1999)

    (a) ``Producer Price Index'' (PPI), as used in this clause, means 
the originally released index, not seasonally adjusted, published by the 
Bureau of Labor Statistics, U.S. Department of Labor (Labor) for product 
code ____ found under Table ____.
    (b) During the term of the contract, the award price may be adjusted 
once upward or downward a maximum of *____ percent. Any price adjustment 
for the product code shall be based upon the percentage change in the 
PPI released in the month prior to the initial month of the contract 
period specified in the solicitation for sealed bidding or the month 
prior to award in negotiation (the base index) and the PPI released 12 
months later (the updated index). The formula for determining the 
Adjusted Contract Price (ACP) applicable to shipments for the balance of 
the contract period is-
[GRAPHIC] [TIFF OMITTED] TR09JY99.000

    (c) If the PPI is not available for the month of the base index or 
the updated index, the month with the most recently published PPI prior 
to the month determining the base index or updated index shall be used.
    (d) If a product code is discontinued, the Government and the 
Contractor will mutually agree to substitute a similar product code. If 
Labor designates an index with a new title and/or code number as 
continuous with the product code specified above, the new index shall be 
used.
    (e) Unless the Contractor's written request for a price adjustment 
resulting from the application of the formula in (b) above is received 
by the Contracting Officer within 30 calendar days of the release of the 
updated index, the Contractor shall have waived its right to an upward 
price adjustment for the balance of the contract. Alternatively, the 
Contracting Officer will unilaterally adjust the award price downward 
when appropriate using the updated index defined in (b) above.
    (f) Price adjustments shall be effective upon execution of a 
contract modification by the Government or on the 31st day following the 
release of the updated index, whichever is later, shall indicate the 
updated index and percent of change as well as the ACP, and shall not 
apply to delivery orders issued before the effective date.

                             (End of clause)

    Alternate I (SEP 1999). As prescribed in 516.203-4(b) (1) and (2), 
substitute the following paragraphs (b), (e) and (f) for paragraphs (b), 
(e) and (f) of the basic clause:

    (b) In any option period, the contract price may be adjusted upward 
or downward a maximum of *____ percent.
    (1) For the first option period, any price adjustment for the 
product code shall be based upon the percentage change in the PPI 
released in the month prior to the initial month of the contract period 
specified in the solicitation for sealed bidding or the month prior to 
award in negotiation (the base index) and the PPI released in the third 
month before completion of the initial contract period stated in the 
solicitation (the updated index). This initial contract period may be 
less than 12 months. The formula for determining the Adjusted Contract 
Price (ACP) applicable to shipments during the first option period is--
[GRAPHIC] [TIFF OMITTED] TR09JY99.001

    (2) For any subsequent option period, the price adjustment shall be 
the percentage change between the previously updated index (the new base 
index) and the PPI released 12 months later (the most recent updated 
index). This percentage shall be applied to the Current Contract Price 
(CCP). The formula for determining the ACP applicable to shipments for 
the subsequent option period(s) is--
[GRAPHIC] [TIFF OMITTED] TR09JY99.002

    (e) Unless the Contractor's written request for a price adjustment 
resulting from the application of the formulas in (b) (1) or (2) above 
is received by the Contracting Officer within 30 calendar days of the 
date of the Government's preliminary written notice of its intent to 
exercise the option, the Contractors shall have waived its right to an 
upward price adjustment for that option period. Alternatively, the 
Contracting Officer in its written notice shall exercise the option at 
the CCP or at a reduced price when appropriate using the formulas in (b) 
(1) or (2) above.
    (f) Price adjustments shall be effected by execution of a contract 
modification by the

[[Page 226]]

Government indicating the most recent updated index and percent of 
change and shall apply to delivery orders placed on or after the first 
day of the option period.

    Alternate II (SEP 1999). As prescribed in 516.203-4(b)(2), add the 
following paragraph (g) to the basic clause.

    (g) No price adjustment will be made unless the percentage in the 
PPI is at least **__ percent.

    * The appropriate percentage should be determined based upon the 
historical trend in the PPI for the product code. A ceiling of more than 
10 percent must be approved by the Contracting Director.
    ** The Contracting Officer should insert a lower percent than the 
maximum percentage stated in paragraph (b) of the clause.



Sec. 552.216-72  Placement of Orders.

    As prescribed in 516.506, inset the following clause:

                     Placement of Orders (SEP 1999)

    (a) Delivery orders (orders) will be placed by:
    [Contracting Officer insert names of Federal agencies]
    (b) Orders may be placed through Electronic Data Interchange (EDI) 
or mailed in paper form. EDI orders shall be placed using the American 
National Standards Institute (ANSI) X12 Standard for Electronic Data 
Interchange (EDI) format.
    (c) If the Contractor agrees, GSA's Federal Supply Service (FSS) 
will place all orders by EDI using computer-to-computer EDI. If 
computer-to-computer EDI is not possible, FSS will use an alternative 
EDI method allowing the Contractor to receive orders by facsimile 
transmission. Subject to the Contractor's agreement, other agencies may 
place orders by EDI.
    (d) When computer-to-computer EDI procedures will be used to place 
orders, the Contractor shall enter into one or more Trading Partner 
Agreements (TPA) with each Federal agency placing orders electronically 
in order to ensure mutual understanding by the parties of certain 
electronic transaction conventions and to recognize the rights and 
responsibilities of the parties as they apply to this method of placing 
orders. The TPA must identify, among other things, the third party 
provider(s) through which electronic orders are placed, the transaction 
sets used, security procedures, and guidelines for implementation. 
Federal agencies may obtain a sample format to customize as needed from 
the office specified in (g) below.
    (e) The Contractor shall be responsible for providing its own 
hardware and software necessary to transmit and receive data 
electronically. Additionally, each party to the TPA shall be responsible 
for the costs associated with its use of third party provider services.
    (f) Nothing in the TPA will invalidate any part of this contract 
between the Contractor and the General Services Administration. All 
terms and conditions of this contract that otherwise would be applicable 
to a mailed order shall apply to the electronic order.
    (g) The basic content and format of the TPA will be provided by:
    General Services Administration, Acquisition Operations and 
Electronic Commerce Center (FCS), Washington, DC 20406
    Telephone: [Contracting officer insert appropriate telephone 
numbers]
    FAX:

                             (End of clause)

    Alternate I (SEP 1999). As prescribed in 516.506, substitute the 
following paragraphs (a), (b), (c), and (d) for paragraphs (a), (b), 
(c), and (d) of the basic clause:

    (a) All delivery orders (orders) under this contract will be placed 
by the General Services Administration's Federal Supply Service (FSS). 
The Contractor is not authorized to accept orders from any other agency. 
Violation of this restriction may result in termination of the contract 
pursuant to the default clause of this contract.
    (b) All orders shall be placed by Electronic Data Interchange (EDI) 
using the American National Standards Institute (ANSI) X12 Standard for 
Electronic Data Interchange (EDI) format.
    (c) If the Contractor agrees, transmission will be computer-to-
computer EDI. If computer-to-computer EDI is not possible, FSS will use 
an alternative EDI method allowing the Contractor to receive orders by 
facsimile transmission.
    (d) When computer-to-computer EDI procedures will be used to place 
orders, the Contractor shall enter into a Trading Partner Agreement 
(TPA) with FSS in order to ensure mutual understanding by the parties of 
certain electronic transaction conventions and to recognize the rights 
and responsibilities of the parties as they apply to this method of 
placing orders. The TPA must identify among other things, the third 
party provider(s) through which electronic orders are placed, the 
transaction sets used, security procedures, and guidelines for 
implementation.
    Alternate II (SEP 1999). As prescribed in 516.506(c), substitute the 
following paragraph (a) for paragraph (a) of the basic clause:

    (a) The organizations listed below may place orders under this 
contract. Questions

[[Page 227]]

regarding organizations authorized to use this schedule should be 
directed to the Contracting Officer.
    (1) Executive agencies.
    (2) Other Federal agencies.
    (3) Mixed-ownership Government corporations.
    (4) The District of Columbia.
    (5) Government contractors authorized in writing by a Federal agency 
pursuant to 48 CFR 51.1.
    (6) Other activities and organizations authorized by statute or 
regulation to use GSA as a source of supply.



Sec. 552.216-73  Ordering Information.

    As prescribed in 516.506(c), insert the following provision:

                     Ordering Information (SEP 1999)

    (a) In accordance with the Placement of Orders clause of this 
solicitation, the offeror elects to receive orders placed by GSA's 
Federal Supply Service (FSS) by either {time}  facsimile transmission or 
{time}  computer-to-computer Electronic Data Interchange (EDI).
    (b) An offeror electing to receive computer-to-computer EDI is 
requested to indicate below the name, address, and telephone number of 
the representative to be contacted regarding establishment of an EDI 
interface.

_______________________________________________________________________

_______________________________________________________________________

_______________________________________________________________________

    (c) An offeror electing to receive orders by facsimile transmission 
is requested to indicate below the telephone number(s) for facsimile 
transmission equipment where orders should be forwarded.

_______________________________________________________________________

_______________________________________________________________________

_______________________________________________________________________

    (d) For mailed orders, the offeror is requested to include the 
postal mailing address(es) where paper form orders should be mailed.

_______________________________________________________________________

_______________________________________________________________________

_______________________________________________________________________

                           (End of provision)

    Alternate I (SEP 1999). As prescribed in 516.506(b), delete 
paragraph (d) of the basic provision.
    Alternate II (SEP 1999). As prescribed in 516.506(b), add paragraph 
(e) to the basic provision.

    (e) Offerors marketing through dealers are requested to indicate 
below whether those dealers will be participating in the proposed 
contract.

    Yes (  )    No (  )

    If ``yes'' is checked, ordering information to be inserted above 
shall reflect that in addition to offeror's name, address, and facsimile 
transmission telephone number, orders can be addressed to the offeror's 
name, c/o nearest local dealer. In this event, two copies of a list of 
participating dealers shall accompany this offer, and shall also be 
included in Contractor's Federal Supply Schedule pricelist.



Sec. 552.217-70  Evaluation of Options.

    As prescribed in 517.208(a), insert the following provision:

                    Evaluation of Options (AUG 1990)

    (a) The Government will evaluate offers for award purposes by 
determining the lowest base period price. When option year pricing is 
based on a formula (e.g., changes in the Producer Price Index or other 
common standard); option year pricing is automatically' considered when 
evaluating the base year price, as any change in price will be uniformly 
related to changes in market conditions. All options are therefore 
considered to be evaluated. Evaluation of options will not obligate the 
Government to exercise the option(s).
    (b) The Government will reject the offer if exceptions are taken to 
the price provisions of the Economic Price Adjustment clause, unless the 
exception results in a lower maximum option year price. Such offers will 
be evaluated without regard to the lower option year(s) maximum. 
However, if the offeror offering a lower maximum is awarded a contract, 
the award will reflect the lower maximum.



Sec. 552.217-71  Notice Regarding Option(s).

    As prescribed in 517.208(b), insert the following provision:

                  Notice Regarding Option(s) (NOV 1992)

    The General Services Administration (GSA) has included an option to 
[Insert ``purchase additional quantities of supplies or services'' or 
``extend the term of this contract'' or ``purchase additional quantities 
of supplies or services and to extend the term of this contract''] in 
order to demonstrate the value it places on quality performance by 
providing a mechanism for continuing a contractual relationship with a 
successful Offeror that performs at a level which meets or exceeds GSA's 
quality performance expectations as communicated to the Contractor, in 
writing, by the Contracting Officer or designated representative. When 
deciding whether to exercise the option, the Contracting Officer will 
consider the quality of the Contractor's past

[[Page 228]]

performance under this contract in accordance with 48 CFR 517.207.

                           (End of provision)



Sec. 552.219-70  Allocation of Orders--Partially Set-Aside Items.

    As prescribed in 519.508, insert the following clause:

       Allocation of Orders--Partially Set-Aside Items (SEP 1999)

    Where the set-aside portion of an item or group of items is awarded 
to a Contractor other than the one receiving the award on the 
corresponding non-set-aside portion, the Government will divide the 
requirements to be ordered between the two Contractors with the 
objective of achieving, as nearly as possible, a 50/50 division of the 
total value of orders placed after the award of the set-aside portion. 
In no case will this division vary by more than a 60/40 division (with 
either the non-set-aside or set-aside Contractor receiving the larger 
portion) from the time of the award of the set-aside portion.

                             (End of clause)



Sec. 552.219-71  Notice to Offerors of Subcontracting Plan Requirements.

    As prescribed in 519.708, insert the following provision:

    Notice to Offerors of Subcontracting Plan Requirements (SEP 1999)

    The General Services Administration (GSA) is committed to assuring 
that maximum practicable opportunity is provided to small, HUBZone 
small, small disadvantaged, and women-owned small business concerns to 
participate in the performance of this contract consistent with its 
efficient performance. GSA expects any subcontracting plan submitted 
pursuant to FAR 52.219-9, Small Business Subcontracting Plan, to reflect 
this commitment. Consequently, an offeror, other than a small business 
concern, before being awarded a contract exceeding $500,000 ($1,000,000 
for construction), must demonstrate that its subcontracting plan 
represents a creative and innovative program for involving small, 
HUBZone small, small disadvantaged, and women-owned small business 
concerns as subcontractors in the performance of this contract.

                           (End of provision)



Sec. 552.219-72  Preparation, Submission, and Negotiation of 
          Subcontracting Plans.

    As prescribed in 519.708(b), insert the following provision:

 Preparation, Submission, and Negotiation of Subcontracting Plans (SEP 
                                  1999)

    (a) An offeror, other than a small business concern, submitting an 
offer that exceeds $500,000 ($1,000,000 for construction) shall submit a 
subcontracting plan with its initial offer. The subcontracting plan will 
be negotiated concurrently with price and any required technical and 
management proposals, unless the offeror submits a previously-approved 
commercial products plan.
    (b) Maximum practicable utilization of small, HUBZone small, small 
disadvantaged, and women-owned small business concerns as subcontractors 
is a matter of national interest with both social and economic benefits. 
The General Services Administration (GSA) expects that an offeror's 
subcontracting plan will reflect a commitment to assuring that small, 
HUBZone small, small disadvantaged, and women-owned small business 
concerns are provided the maximum practicable opportunity, consistent 
with efficient contract performance, to participate as subcontractors in 
the performance of the resulting contract. An offeror submitting a 
commercial products plan can reflect this commitment through 
subcontracting opportunities it provides that relate to the offeror's 
production generally; i.e., for both its commercial and Government 
business.
    (c) GSA believes that this potential contract provides significant 
opportunities for the use of small, HUBZone small, small disadvantaged, 
and women-owned small business concerns as subcontractors. Consequently, 
in addressing the eleven elements described at FAR 52.219-9(d) of the 
clause in this contract entitled Small Business Subcontracting Plan, the 
offeror shall:
    (1) Demonstrate that its subcontracting plan represents a creative 
and innovative program for involving small, HUBZone small, small 
disadvantaged, and women-owned small business concerns in performing the 
contract.
    (2) Include a description of the offeror's subcontracting strategies 
used in any previous contracts, significant achievements, and how this 
plan will build upon those earlier achievements.
    (3) Demonstrate through its plan that it understands the small 
business subcontracting program's objectives and GSA's expectations, and 
it is committed to taking those actions necessary to meet these goals or 
objectives.
    (d) In determining the acceptability of any subcontracting plan, the 
Contracting Officer will take each of the following actions:
    (1) Review the plan to verify that the offeror demonstrates an 
understanding of the small business subcontracting program's objectives 
and GSA's expectations with respect

[[Page 229]]

to the program and has included all the information, goals, and 
assurances required by FAR 52.219-9.
    (2) Consider previous goals and achievements of contractors in the 
small industry.
    (3) Consider information and potential sources obtained from 
agencies administering national and local preference programs and other 
advocacy groups in evaluating whether the goals stated in the plan 
adequately reflect the anticipated potential for subcontracting to 
small, HUBZone small, small disadvantaged, and women-owned small 
business concerns.
    (4) Review the offeror's description of its strategies, historical 
performance and significant achievements in placing subcontracts for the 
same or similar products or services with small, HUBZone small, small 
disadvantaged, and women-owned small business concerns. The offeror's 
description can apply to commercial as well as previous Government 
contracts.
    (e) Failure to submit an acceptable subcontracting plan and/or 
correct deficiencies in a plan within the time specified by the 
Contracting Officer shall make the offeror ineligible for award.

                           (End of provision)



Sec. 552.219-73  Goals for Subcontracting Plan.

    As prescribed in 519.708(c), insert the following provision:

                Goals for Subcontracting Plan (SEP 1999)

    (a) Maximum practicable utilization of small, HUBZone small, small 
disadvantaged, and women-owned small business concerns as subcontractors 
is a matter of national interest with both social and economic benefits.
    (1) The General Service Administration's (GSA's) commitment to 
ensuring that maximum practicable opportunity is provided to small, 
HUBZone small, small disdvantaged, and women-owned small business 
concerns to participate as subcontractors in the performance of this 
contract, consistent with its efficient performance, must be reflected 
in the offeror's subcontracting plan submitted pursuant to the clause of 
this contract at FAR 52.219-9, Small Business Subcontracting Plan.
    (2) In addressing the eleven elements described at FAR 52.219-9(d), 
the offeror shall demonstrate that its subcontracting plan represents a 
creative and innovative program for involving small, HUBZone small, 
small disadvantaged, and women-owned small business concerns in 
performing this contract. An offeror submitting a commercial products 
plan can demonstrate its commitment in providing maximum practicable 
opportunities through subcontracting opportunities it provides to small, 
HUBZone small, small disadvantaged, and women-owned small business 
concerns that relate to the offeror's production generally; i.e., for 
both its commercial and Government business.
    (3) The subcontracting plan shall include a description of the 
offeror's subcontracting strategies used in previous contracts and 
significant achievements, with an explanation of how this plan will 
build upon those earlier achievements. Additionally, the offeror shall 
demonstrate through its plan that it understands the small business 
subcontracting program's objectives, GSA's expectations, and is 
committed to taking those actions necessary to meet these goals or 
objectives.
    (b) GSA believes that this contract provides significant 
opportunities for the use of small, HUBZone small, small disadvantaged, 
and women-owned small business concerns as subcontractors. Accordingly, 
it is anticipated that an acceptable subcontracting plan will contain at 
least the following goals:


Small Business.......................................        __ percent.
HUBZone Small Business...............................        __ percent.
Small Disadvantaged Business.........................        __ percent.
Women-Owned Small Business...........................        __ percent.
 

    Note: Target goals are expressed as a percentage of planned 
subcontracting dollars.

    (c) In determining the acceptability of any subcontracting plan, the 
Contracting Officer will--
    (1) Review the plan to verify that the offeror has demonstrated an 
understanding of the small business subcontracting program's objectives 
and GSA's expectations with respect to the programs and has included all 
the information, goals, and assurances required by FAR 52.219-9;
    (2) Consider previous goals and achievements of contractors in the 
same industry;
    (3) Consider information and potential sources obtained from 
agencies administering national and local preference programs and other 
advocacy groups in evaluating whether the goals stated in the plan 
adequately reflect the anticipated potential for subcontracting to 
small, HUBZone small, small disadvantaged, and women-owned small 
business concerns; and
    (4) Review the offeror's description of its strategies, historical 
performance and significant achievements in placing subcontracts for the 
same or similar products or services with small, HUBZone small, small 
disadvantaged, and women-owned small business concerns. The offeror's 
description can apply to commercial as well as previous Government 
contracts.
    (d) Failure to submit an acceptable subcontracting plan and/or 
correct deficiencies in a plan within the time specified by the 
Contracting Officer shall make the offeror ineligible for award.


[[Page 230]]



                           (End of provision)

    Alternate I (SEP 1999). As prescribed in 519.708(c)(2), delete 
paragraph (b) of the basic provision and redesignate paragraphs (c) and 
(d) as paragraphs (b) and (c).



Sec. 552.219-74  Section 8(a) Direct Award.

    As prescribed in 519.870-8, insert the following clause:

                  Section 8(a) Direct Award (SEP 1999)

    (a) This contract is issued as a direct award between the 
contracting activity and the 8(a) Contractor pursuant to the Memorandum 
of Understanding between the Small Business Administration (SBA) and the 
General Services Administration. SBA retains the responsibility for 8(a) 
certifications, 8(a) eligibility determinations, and related issues, and 
will provide counseling and assistance to the 8(a) contractor under the 
8(a) program. The cognizant SBA district office is: [Complete at time of 
award]
    (b) The contracting activity is responsible for administering the 
contract and taking any action on behalf of the Government under the 
terms and conditions of the contract. However, the contracting activity 
shall give advance notice to SBA before it issues a final notice 
terminating performance, either in whole or in part, under the contract. 
The contracting activity shall also coordinate with SBA prior to 
processing any advance payments or novation agreements. The contracting 
activity may assign contract administration functions to a contract 
administration office.
    (c) The Contractor agrees:
    (1) To notify the Contracting Officer, simultaneous with its 
notification to SBA (as required by SBA's 8(a) regulations), when the 
owner or owners upon whom 8(a) eligibility is based plan to relinquish 
ownership or control of the concern. Consistent with 15 U.S.C. 
637(a)(21), transfer of ownership or control shall result in termination 
of the contract for convenience, unless SBA waives the requirement for 
termination prior to the actual relinquishing of ownership and control.
    (2) To the requirements of 52.219-14, Limitations on Subcontracting.

                             (End of clause)



Sec. 552.223-70  Hazardous Substances.

    As prescribed in 523.303(a), insert the following clause:

                     Hazardous Substances (MAY 1989)

    (a) If the packaged items to be delivered under this contract are of 
a hazardous substance and ordinarily are intended or considered to be 
for use as a household item, this contract is subject to the Federal 
Hazardous Materials Act, as amended (15 U.S.C. 1261-1276), implementing 
regulations thereof (16 CFR Chapter II), and Federal Standard No. 123, 
Marking for Shipment (Civil Agencies), issue in effect on the date of 
this solicitation.
    (b) The packaged items to be delivered under this contract are 
subject to the preparation of shipping documents, the preparation of 
items for transportation, shipping container construction, package 
making, package labeling, when required, shipper's certification of 
compliance, and transport vehicle placarding in accordance with Parts 
171 through 178 of 49 CFR and the Hazardous Materials Transportation 
Act.
    (c) The minimum packaging acceptable for packaging Department of 
Transportation regulated hazardous materials shall be those in 49 CFR 
173.

                             (End of clause)



Sec. 552.223-71  Nonconforming Hazardous Materials.

    As prescribed in 523.303(b), insert the following clause:

              Nonconforming Hazardous Materials (SEP 1999)

    (a) Nonconforming supplies that contain hazardous material or that 
may expose persons who handle or transport the supplies to hazardous 
material and which require replacement under the inspection and/or 
warranty clauses of this contract shall be reshipped to the Contractor 
at the Contractor's expense. The Contractor agrees to accept return of 
these nonconforming supplies and to pay all costs occasioned by their 
return.
    (b) ``Hazardous materials,'' as used in this clause, includes any 
material defined as hazardous under the latest version of Federal 
Standard No. 313 (including revisions adopted during the term of the 
contract).
    (c) If the Contractor fails to provide acceptable disposition 
instructions for the nonconforming supplies within 10 days from the date 
of the Government's request (or such longer period as may be agreed to 
between the Contracting Officer and the Contractor), or fails to accept 
return of the reshipped nonconforming supplies, such failure:
    (1) may be interpreted as a willful failure to perform,
    (2) may result in termination of the contract for default and
    (3) shall be considered by the Contracting Officer in determining 
the responsibility of the Contractor for any future award (see FAR 
9.104-3(b) and 9.406-2).

[[Page 231]]

    (d) Pending final resolution of any dispute, the Contractor shall 
promptly comply with the decision of the Contracting Officer.

                             (End of clause)



Sec. 552.223-72  Hazardous Material Information.

    As prescribed in 523.370, insert the following provision:

                Hazardous Material Information (SEP 1999)

    Offeror shall indicate for each national stock number (NSN) the 
following information:

------------------------------------------------------------------------
                    DOT shipping   DOT hazard
       NSN              name         class         DOT label required
------------------------------------------------------------------------
                                               Yes [  ]    No [  ]
                                               Yes [  ]    No [  ]
                                               Yes [  ]    No [  ]
------------------------------------------------------------------------

                           (End of provision)



Sec. 552.225-70  Notice of Procurement Restriction--Hand or Measuring 
          Tools or Stainless Steel Flatware.

    As prescribed in 525.1101, insert the following clause:

Notice of Procurement Restriction--Hand or Measuring Tools or Stainless 
                        Steel Flatware (SEP 1999)

    (a) Awards under this solicitation will only be made to offerors 
that will furnish hand or measuring tools or stainless steel flatware 
that are domestic end products. Pursuant to the requirements of the 
current Department of Defense Appropriations Act, GSA has determined, in 
accordance with Section 6-104.4 of the Armed Services Procurement 
Regulation (6/15/70)(32 CFR 6-104.4), that it is in the national 
interest to reject foreign products.
    As used in this clause, a ``domestic end product'' is--
    (1) Any hand or measuring tool, except for an electric or air-motor 
driven hand tool, or stainless steel flatware, wholly produced or 
manufactured, including all components, in the United States or its 
possessions; or
    (2) Any electric or air-motor driven hand tool if the cost of its 
components produced or manufactured in the United States exceeds 75 
percent of the cost of all its components.
    (b) Tool kits or sets, being procured under this solicitation, will 
not be considered domestic end products if any individual tool 
classified in FSC Group 51 or 52 and included in a tool kit or set is 
not a domestic end product as defined in paragraph (a) of this clause. 
The restrictions of this clause do not apply to individual hand or 
measuring tools that are contained in the tool kit or set but are not 
classified in FSC Group 51 or 52.

                             (End of clause)

[64 FR 37229, July 9, 1999, as amended at 65 FR 41379, July 5, 2000]



Sec. 552.227-70  Government Rights (Unlimited).

    As prescribed in 527.409, insert the following clause:

                Government Rights (Unlimited) (MAY 1989)

    The Government shall have unlimited rights in all drawings, designs, 
specifications, notes and other works developed in the performance of 
this contract, including the right to use same on any other Government 
design or construction without additional compensation to the 
Contractor. The Contractor hereby grants to the Government a paid-up 
license throughout the world to all such works to which he may assert or 
establish any claim under design patent or copyright laws. The 
Contractor for a period of three years after completion of the project 
agrees to furnish the original or copies of all such works on the 
request of the Contracting Officer.

                             (End of clause)



Sec. 552.227-71  Drawings and Other Data to Become Property of 
          Government.

    As prescribed in 527.409(b), substitute the following clause:

   Drawings and Other Data to Become Property of Government (MAY 1989)

    All designs, drawings, specifications, notes and other works 
developed in the performance of this contract shall become the sole 
property of the Government and may be used on any other design or 
construction without additional compensation to the Contractor. The 
Government shall be considered the ``person for whom the work was 
prepared'' for the purpose of authorship in any copyrightable work under 
Section 201(b) of Title 17, United States Code. With respect thereto, 
the Contractor agrees not to assert or authorize others to assert any 
rights nor establish any claim under the design patent or copyright 
laws. The Contractor for a period of three years after completion of the 
project agrees to furnish all retained works on the request of the 
Contracting Officer. Unless otherwise provided in this contract, the 
Contractor shall have the right to retain copies of works beyond such 
period.


[[Page 232]]



                             (End of clause)



Sec. 552.228-70  Workers' Compensation Laws.

    As prescribed in 528.310(a), insert the following clause:

                  Workers' Compensation Laws (SEP 1999)

    The Act of June 25, 1936, 49 Stat. 1938 (40 U.S.C. 290) authorizes 
the constituted authority of the several States to apply their workers' 
compensation laws to all lands and premises owned or held by the United 
States.

                             (End of clause)



Sec. 552.229-70  Federal, State, and Local Taxes.

    As prescribed in 529.401-70, insert the following clause:

               Federal, State, and Local Taxes (APR 1984)

    The contract price includes all applicable Federal, State, and local 
taxes. No adjustment will be made to cover taxes which may subsequently 
be imposed on this transaction or changes in the rates of currently 
applicable taxes. However, the Government will, upon the request of the 
Contractor, furnish evidence appropriate to establish exemption from any 
tax from which the Government is exempt and which was not included in 
the contract price.

                             (End of clause)



Sec. 552.229-71  Federal Excise Tax--DC Government.

    As prescribed in 529.401-71, insert the following clause:

              Federal Excise Tax--DC Government (SEP 1999)

    If the District of Columbia cites an Internal Revenue Tax Exempt 
Certificate Number on orders placed under this contract, the Contractor 
shall bill shipments to the District of Columbia at prices exclusive of 
Federal excise tax and show the amount of such tax on the invoice.

                             (End of clause)



Sec. 552.232-1  Payments.

    As prescribed in 532.7104, insert the following clause:

              Payments (APR 1984) (Deviation FAR 52.232-1)

    (a) The Government shall pay the Contractor, without submission of 
invoices or vouchers, 30 days after the service period, the prices 
stipulated in this contract for supplies delivered and accepted or 
services rendered and accepted, less any deductions provided in this 
contract.
    (b) Unless otherwise specified in this contract, the Government will 
make payment on partial deliveries accepted by the Government if either:
    (1) The amount due on the deliveries warrants it.
    (2) The Contractor requests it and the amount due on the deliveries 
is at least $1,000 or 50 percent of the total contract price.
    (c) When processing payment, GSA's Finance Office will automatically 
generate the 12 digit invoice number using the ACT number assigned to 
the contract, followed by an abbreviated month and year of service 
(e.g., 84261554JUN7, for June 1997). The ACT number appears on the 
contract award document.

                             (End of clause)



Sec. 552.232-8  Discounts for Prompt Payment.

    As prescribed in 532.206, insert the following clause:

    Discounts for Prompt Payment (APR 1989) (Deviation FAR 52.232-8)

    (a) Discounts for early payment (hereinafter referred to as 
``discounts'' or ``the discount'') will be considered in evaluating the 
relationship of the offeror's concessions to the Government vis-a-vis 
the offeror's concessions to its commercial customers, but only to the 
extent indicated in this clause.
    (b) Discounts will not be considered to determine the low offeror in 
the situation described in the ``Offers on Identical Products'' 
provision of this solicitation.
    (c) Uneconomical discounts will not be considered as meeting the 
criteria for award established by the Government. In this connection, a 
discount will be considered uneconomical if the annualized rate of 
return for earning the discount is lower than the ``value of funds'' 
rate established by the Department of the Treasury and published 
quarterly in the Federal Register. The ``value of funds'' rate applied 
will be the rate in effect on the date specified for the receipt of 
offers.
    (d) Agencies required to use the resultant schedule will not apply 
the discount in determining the lowest delivered price pursuant to the 
FPMR, 41 CFR 101-26.408, if the agency determines that payment will 
probably not be made within the discount period offered. The same is 
true if the discount is considered uneconomical at the time of placement 
of the order.

[[Page 233]]

    (e) Discounts for early payment may be offered either in the 
original offer or on individual invoices submitted under the resulting 
contract. Discounts offered will be taken by the Government if payment 
is made within the discount period specified.
    (f) Discounts that are included in offers become a part of the 
resulting contracts and are binding on the Contractor for all orders 
placed under the contract. Discounts offered only on individual invoices 
will be binding on the Contractor only for the particular invoice on 
which the discount is offered.
    (g) In connection with any discount offered for prompt payment, time 
shall be computed from the date of the invoice. For the purpose of 
computing the discount earned, payment shall be considered to have been 
made on the date which appears on the payment check or the date on which 
an electronic funds transfer was made.

                             (End of clause)



Sec. 552.232-23  Assignment of Claims.

    As prescribed in 532.806, insert the following clause:

                     Assignment of Claims (SEP 1999)

    Because this is a requirements or indefinite quantity contract under 
which more than one agency may place orders, paragraph (a) of the 
Assignment of Claims clause (FAR 52.232-23) is inapplicable and the 
following is substituted therefor:
    In order to prevent confusion and delay in making payment, the 
Contractor shall not assign any claim(s) for amounts due or to become 
due under this contract. However, the Contractor is permitted to assign 
separately to a bank, trust company, or other financial institution, 
including any Federal lending agency, under the provisions of the 
Assignment of Claims Act, as amended, 31 U.S.C. 3727, 41 U.S.C. 15 
(hereinafter referred to as ``the Act''), all amounts due or to become 
due under any order amounting to $1,000 or more issued by any Government 
agency under this contract. Any such assignment takes effect only if and 
when the assignee files written notice of the assignment together with a 
true copy of the instrument of assignment with the contracting officer 
issuing the order and the finance office designated in the order to make 
payment. Unless otherwise stated in the order, payments to an assignee 
of any amounts due or to become due under any order assigned may, to the 
extent specified in the Act, be subject to reduction or set-off.

                             (End of clause)



Sec. 552.232-25  Prompt Payment.

    As prescribed in 532.908(a)(2), insert the following clause:

           Prompt Payment (JUL 1998) (Deviation FAR 52.232-25)

    Notwithstanding any other payment clause in this contract, the 
Government will make invoice payments and contract financing payments 
under the terms and conditions specified in this clause. Payment shall 
be considered as being made on the day a check is dated or the date of 
an electronic funds transfer. Definitions of pertinent terms are set 
forth in section 32.902 of the Federal Acquisition Regulation. All days 
referred to in this clause are calendar days, unless otherwise 
specified. (However, see subparagraph (a)(4) of this clause concerning 
payments due on Saturdays, Sundays, and legal holidays.)
    (a) Invoice payments. (1) The due date for making invoice payments 
by the designated payment office is:
    (i) For orders placed electronically by the General Services 
Administration (GSA) Federal Supply Service (FSS), and to be paid by GSA 
through electronic funds transfer (EFT), the later of the following two 
events:
    (A) The 10th day after the designated billing office receives a 
proper invoice from the Contractor. If the designated billing office 
fails to annotate the invoice with the date of receipt at the time of 
receipt, the invoice payment due date shall be the 10th day after the 
date of the Contractor's invoice; provided the Contractor submitted a 
proper invoice and no disagreement exists over quantity, quality, or 
Contractor compliance with contract requirements.
    (B) The 10th day after Government acceptance of supplies delivered 
or services performed by the Contractor.
    (ii) For all other orders, the later of the following two events:
    (A) The 30th day after the designated billing office receives a 
proper invoice from the Contractor. If the designated billing office 
fails to annotate the invoice with the date of receipt at the time of 
receipt, the invoice payment due date shall be the 30th day after the 
date ofthe Contractor's invoice; provided the Contractor submitted a 
proper invoice and no disagreement exists over quantity, quality, or 
Contractor compliance with contract requirements.
    (B) The 30th day after Government acceptance of supplies delivered 
or services performed by the Contractor.
    (iii) On a final invoice, if the payment amount is subject to 
contract settlement actions, acceptance occurs on the effective date of 
the contract settlement.

[[Page 234]]

    (2) The General Services Administration will issue payment on the 
due date in (a)(1)(i) above if the Contractor complies with full cycle 
electronic commerce. Full cycle electronic commerce includes all the 
following elements:
    (i) The Contractor must receive and fulfill electronic data 
interchange (EDI) purchase orders (transaction set 850).
    (ii) The Contractor must generate and submit to the Government valid 
EDI invoices (transaction set 810) or submit invoices through the GSA 
Finance Center Internet-based invoice process. Internet-based invoices 
must be submitted using procedures provided by GSA.
    (iii) The Contractor's financial institution must receive and 
process, on behalf of the Contractor, EFT payments through the Automated 
Clearing House (ACH) system.
    (iv) The EDI transaction sets in (i) through (iii) above must adhere 
to implementation conventions provided by GSA.
    (3) If any of the conditions in(a)(2) above do not occur, the 10 day 
payment due dates in (a)(1) become 30 day payment due dates.
    (4) Certain food products and other payments.
    (i) Due dates on Contractor invoices for meat, meat food products, 
or fish; perishable agricultural commodities; and dairy products, edible 
fats or oils, and food products prepared from edible fats or oils are--
    (A) For meat or meat food products, as defined in section 2(a)(3) of 
the Packers and Stockyard Act of 1921 (7 U.S.C. 182 (3)), and as further 
defined in Pub. L. 98-181, including any edible fresh or frozen poultry 
meat, any perishable poultry meat food product, fresh eggs, an any 
perishable egg product, as close as possible to, but not later than, the 
7th day after product delivery.
    (B) For fresh or frozen fish, as defined in section 204(3) of the 
Fish and Seafood Promotion Act of 1986 (16 U.S.C. 4003(3)), as close as 
possible to, but not later than, the 7th day after product delivery.
    (C) For perishable agricultural commodities, as defined in section 
1(4) of the Perishable Agricultural Commodities Act of 1930 (7 U.S.C. 
499a(4)), as close as possible to, but not later than, the 10th day 
after product delivery, unless another date is specified in the 
contract.
    (D) For daily products, as defined in section 111(e) of the Dairy 
Production Stabilization Act of 1983 (7 U.S.C. 4502(e)), edible fats or 
oils, and food products prepared from edible fats or oils, as close as 
possible to, but not later than, the 10th day after the date on which a 
proper invoice has been received. Liquid milk, cheese, certain processed 
cheese products, butter, yogurt, ice cream, mayonnaise, salad dressing, 
and other similar products, fall within this classification. Nothing in 
the Act limits this classification to refrigerated products. When 
questions arise regarding the proper classification of a specific 
product, prevailing industry practices will be followed in specifying a 
contract payment due date. The burden of proof that a classification of 
a specific product is, in fact, prevailing industry practice is upon the 
Contractor making the representation.
    (ii) If the contract does not require submission of an invoice for 
payment (e.g., periodic lease payments), the due date will be as 
specified in the contract.
    (5) Contractor's invoice. The Contractor shall prepare and submit 
invoices to the designated billing office specified in the contract. 
Notwithstanding paragraph (g) of the clause at FAR 52.212-4, Contract 
Terms and Conditions--Commercial Items, if the Contractor submits hard-
copy invoices, submit only an original invoice. No copies of the invoice 
are required. A proper invoice must include the items listed in 
subdivisions (a)(5)(i) through (a)(5)(viii) of this clause. If the 
invoice does not comply with these requirements, it shall be returned 
within 7 days after the date the designated billing office received the 
invoice (3 days for meat, meat food products, or fish; 5 days for 
perishable agricultural commodities, edible fats or oils, and food 
products prepared from edible fats or oils), with a statement of the 
reasons why it is not a proper invoice. Untimely notification will be 
taken into account in computing any interest penalty owed the Contractor 
in the manner described in subparagraph (a)(5) of this clause.
    (i) Name and address of the Contractor.
    (ii) Invoice date. (The Contractor is encouraged to date invoices as 
close as possible to the date of the mailing or transmission.)
    (iii) Contract number or other authorization for supplies delivered 
or services preformed (including order number and contract line item 
number).
    (iv) Description, quantity, unit of measure, unit price, an extended 
prices of supplies delivered or services performed.
    (v) Shipping and payment terms (e.g., shipment number and date of 
shipment, prompt payment discount terms). Bill of lading number and 
weight of shipment will be shown for shipments on Government bills or 
lading.
    (vi) Name and address of Contractor official to whom payment is to 
be sent (must be the same as that in the contract or in a proper notice 
of assignment).
    (vii) Name (where practicable), title, phone number, and mailing 
address of person to be notified in the event of a defective invoice.
    (viii) Any other information or documentation required by the 
contract (such as evidence of shipment).
    (ix) While not required, the Contractor is strongly encouraged to 
assign an identification number to each invoice.
    (6) Interest penalty. An interest penalty shall be paid 
automatically by the designated payment office, without request

[[Page 235]]

from the Contractor, if payment is not made by the due date and the 
conditions listed in subdivisions (a)(6)(i) through (a)(6)(iii) of this 
clause are met, if applicable. However, when the due date falls on a 
Saturday, Sunday, or legal holiday when Federal Government offices are 
closed and Government business is not expected to be conducted, payment 
may be made on the following business day without incurring a late 
payment interest penalty.
    (i) A proper invoice was received by the designated billing office.
    (ii) A receiving report or other Government documentation 
authorizing payment was processed, and there was no disagreement over 
quantity, quality, or Contractor compliance with any contract term or 
condition.
    (iii) In the case of a final invoice for any balance of funds due 
the Contractor for supplies delivered or services performed, the amount 
was not subject to further contract settlement actions between the 
Government and the Contractor.
    (7) Computing penalty amount. The interest penalty shall be at the 
rate established by the Secretary of the Treasury under section 12 of 
the Contract Disputes Act of 1978 (41 U.S.C. 611) that is in effect on 
the day after the due date, except where the interest penalty is 
prescribed by other governmental authority (e.g., tariffs). This rate is 
referred to as the ``Renegotiation Board Interest Rate,'' and it is 
published in the Federal Register semiannually on or about January 1 and 
July 1. The interest penalty shall accrue daily on the invoice principal 
payment amount approved by the Government until the payment date of such 
approved principal amount; and will be compounded in 30-day increments 
inclusive from the first day after the due date through the payment 
date. That is, interest accrued at the end of any 30-day period will be 
added to the approved invoice principal payment amount and will be 
subject to interest penalties if not paid in the succeeding 30-day 
period. If the designated billing office failed to notify the Contractor 
of a defective invoice within the periods prescribed in subparagraph 
(a)(5) of this clause, the due date on the corrected invoice will be 
adjusted by subtracting from such date the number of days taken beyond 
the prescribed notification of defects period. Any interest penalty owed 
the Contractor will be based on this adjusted due date. Adjustments will 
be made by the designated payment office for errors in calculating 
interest penalties.
    (i) For the sole purpose of computing an interest penalty that might 
be due the Contractor, Government acceptance shall be deemed to have 
occurred constructively on the 7th day (unless otherwise specified in 
this contract) after the Contractor delivered the supplies or performed 
the services in accordance with the terms and conditions of the 
contract, unless there is a disagreement over quantity, quality or 
Contractor compliance with a contract provision. In the event that 
actual acceptance occurs within the constructive acceptance period, the 
determination of an interest penalty shall be based on the actual date 
of acceptance. The constructive acceptance requirement does, not 
however, compel Government officials to accept supplies or services, 
perform contract administration functions, or make payment prior to 
fulfilling their responsibilities.
    (ii) The following periods of time will not be included in the 
determination of an interest penalty:
    (A) The period taken to notify the Contractor of defects in invoices 
submitted to the Government, but this may not exceed 7 days (3 days for 
meat, meat food products, or fish; 5 days for perishable agricultural 
commodities, dairy products, edible fats or oils, and food products 
prepared from edible fats or oils).
    (B) The period between the defects notice and resubmission of the 
corrected invoice by the Contractor.
    (C) For incorrect electronic funds transfer (EFT) information, in 
accordance with the EFT clause of this contract.
    (iii) Interest penalties will not continue to accrue after the 
filing of a claim for such penalties under the clause at 52.233-1, 
Disputes, or for more than 1 year. Interest penalties of less than $1 
need not be paid.
    (iv) Interest penalties are not required on payment delays due to 
disagreement between the Government and the Contractor over the payment 
amount or other issues involving contract compliance or on amounts 
temporarily withheld or retained in accordance with the terms of the 
contract. Claims involving disputes, and any interest that may be 
payable, will be resolved in accordance with the clause at 52.233-1, 
Disputes.
    (8) Prompt payment discounts. An interest penalty also shall be paid 
automatically by the designated payment office, without request from the 
Contractor, if a discount for prompt payment is taken improperly. The 
interest penalty will be calculated as described in subparagraph (a)(7) 
of this clause on the amount of discount taken for the period beginning 
with the first day after the end of the discount period through the date 
when the Contractor is paid.
    (9) Additional interest penalty.
    (i) If this contract was awarded on or October 1, 1989, a penalty 
amount, calculated in accordance with subdivision (a)(9)(iii) of this 
clause, shall be paid in addition to the interest penalty amount if the 
Contractor--
    (A) Is owed an interest penalty of $1 or more;
    (B) Is not paid the interest penalty within 10 days after the date 
the invoice amount is paid; and

[[Page 236]]

    (C) Makes a written demand to the designated payment office for 
additional penalty payment, in accordance with subdivision (a)(9)(ii) of 
this clause, postmarked not later than 40 days after the invoice amount 
is paid.
    (ii)(A) Contractors shall support written demands for additional 
penalty payments with the following data. No additional data shall be 
required. Contractors shall--
    (1) Specifically assert that late payment interest is due under a 
specific invoice, and request payment of all overdue late payment 
interest penalty and such additional penalty as may be required;
    (2) Attach a copy of the invoice on which the unpaid late payment 
interest was due; and
    (3) State that payment of the principal has been received, including 
the date of receipt.
    (B) Demands must be postmarked on or before the 40th day after 
payment was made, except that--
    (1) If the postmark is illegible or nonexistent, the demand must 
have been received and annotated with the date of receipt by the 
designated payment office on or before the 40th day after payment was 
made; or
    (2) If the postmark is illegible or nonexistent and the designated 
payment office fails to make the required annotation, the demand's 
validity will be determined by the date the Contractor has placed on the 
demand; provided such date is no later than the 40th day after payment 
was made.
    (iii)(A) The additional penalty shall be equal to 100 percent of any 
original late payment interest penalty, except--
    (1) The additional penalty shall not exceed $5,000;
    (2) The additional penalty shall never be less than $25; and
    (3) No additional penalty is owed if the amount of the underlying 
interest penalty is less than $1.
    (B) If the interest penalty ceases to accrue in accordance with the 
limits stated in subdivision (a)(5)(iii) of this clause, the amount of 
the additional penalty shall be calculated on the amount of interest 
penalty that would have accrued in the absence of these limits, subject 
to the overall limits on the additional penalty specified in subdivision 
(a)(7)(iii)(A) of this clause.
    (C) For determining the maximum and minimum additional penalties, 
the test shall be the interest penalty due on each separate payment made 
for each separate contract. The maximum and minimum additional penalty 
shall not be based upon individual invoices unless the invoices are paid 
separately. Where payments are consolidated for disbursing purposes, the 
maximum and minimum additional penalty determination shall be made 
separately for each contract therein.
    (D) The additional penalty does not apply to payments regulated by 
other Government regulations (e.g., payments under utility contracts 
subject to tariffs and regulation).
    (b) Contract financing payments. (1) Due dates for recurring 
financing payments. If this contract provides for contract financing, 
requests for payment shall be submitted to the designated billing office 
as specified in this contract or as directed by the Contracting Officer. 
Contract financing payments shall be made on the [insert day as 
prescribed by Agency head; if not prescribed, insert 30th day] day after 
receipt of a proper contract financing request by the designated billing 
office. In the event that an audit or other review of a specific 
financing request is required to ensure compliance with the terms and 
conditions of the contract, the designated payment office is not 
compelled to make payment by the due date specified.
    (2) Due dates for other contract financing. For advance payments, 
loans, or other arrangements that do not involve recurring submissions 
of contract financing requests, payment shall be in accordance with the 
corresponding contract terms or as directed by the Contracting Officer.
    (3) Interest penalty not applicable. Contract financing payments 
shall not be assessed an interest penalty for payment delays.
    (c) Fast payment procedure due dates. If this contract contains the 
clause at 52.213-1, Fast Payment Procedure, payments will be made within 
15 days after the date of receipt of the invoice.

                             (End of clause)



Sec. 552.232-70  Invoice Requirements.

    As prescribed in 532.111(a), insert the following clause:

                     Invoice Requirements (SEP 1999)

    (a) Invoices shall be submitted in an original only, unless 
otherwise specified, to the designated billing office specified in this 
contract or order.
    (b) Invoices must include the Accounting Control Transaction (ACT) 
number provided below or on the order.

             ACT Number (Contracting Officer insert number)

    (c) In addition to the requirements for a proper invoice specified 
in the Prompt Payment clause on this contract or order, the following 
information or documentation must be submitted with each invoice:

[[Page 237]]

           (Contracting Officer list additional requirements.)

                             (End of clause)



Sec. 552.232-71  Adjusting Payments.

    As prescribed in 532.111(b), insert the following clause:

                      Adjusting Payments (SEP 1999)

    (a) Under the Inspection of Services clause of this contract, 
payments may be adjusted if any services do not conform with contract 
requirements. The Contracting Office or a designated representative will 
inform the Contractor, in writing, of the type and dollar amount of 
proposed deductions by the 10th workday of the month following the 
performance period for which the deductions are to be made.
    (b) The Contractor may, within 10 working days of receipt of the 
notification of the proposed deductions, present to the Contracting 
Officer specific reasons why any or all of the proposed deductions are 
not justified. Reasons must be solidly based and must provide specific 
facts that justify reconsideration and/or adjustment of the amount to be 
deducted. Failure to respond within the 10-day period will be 
interpreted to mean that the Contractor accepts the deductions proposed.
    (c) All or a portion of the final payment may be delayed or withheld 
until the Contracting Officer makes a final decision on the proposed 
deduction. If the Contracting Officer determines that any or all of the 
proposed deductions are warranted, the Contracting Officer shall so 
notify the Contractor, and adjust payments under the contract 
accordingly.

                             (End of clause)



Sec. 552.232-72  Final Payment.

    As prescribed in 532.111(c), insert the following clause:

                        Final Payment (SEP 1999)

    Before final payment is made, the Contractor shall furnish the 
Contracting Officer with a release of all claims against the Government 
relating to this contract, other than claims in stated amounts that are 
specifically excepted by the Contractor from the release. If the 
Contractor's claim to amounts payable under the contract has been 
assigned under Assignment of Claims Act of 1940, as amended (31 U.S. 
3727, 41 U.S.C. 15), a release may also be required of the assignee.

                             (End of clause)



Sec. 552.232-73  Availability of Funds.

    As prescribed in 532.705-1, insert the following clause:

                    Availability of Funds (SEP 1999)

    The authorization of performance of work under this contract during 
the initial contract period and any option or extension period(s) is 
contingent upon the appropriation of funds to procure this service. If 
the contract is awarded, extended, or option(s) exercised, the 
Government's obligation beyond the end of the fiscal year (September 
30), in which the award or extension is made or option(s) exercised, is 
contingent upon the availability of funds from which payment for the 
contract services can be made. No legal liability on the part of the 
Government for payment of any money beyond the end of the each fiscal 
year (September 30) shall arise unless or until funds are made available 
to the Contracting Officer for this procurement and written notice of 
such availability is given to the Contractor.

                             (End of clause)



Sec. 552.232-74  Invoice Payments.

    As prescribed in 532.908 (a)(1), insert the following clause:

                       Invoice Payments (SEP 1999)

    (a) The due date for making invoice payments by the designated 
payment office is:
    (1) For orders placed electronically by the General Services 
Administration (GSA) Federal Supply Service (FSS), and to be paid by GSA 
through electronic funds transfer (EFT), the later of the following two 
events:
    (i) The 10th day after the designated billing office receives a 
proper invoice from the Contractor. If the designated billing office 
fails to annotate the invoice with the date of receipt at the time of 
receipt, the invoice payment due date shall be the 10th day after the 
date of the Contractor's invoice; provided the Contractor submitted a 
proper invoice and no disagreement exists over quantity, quality, or 
Contractor compliance with contract requirements.
    (ii) The 10th day after Government acceptance of supplies delivered 
or services performed by the Contractor.
    (2) For all other orders, the later of the following two events:
    (i) The 30th day after the designated billing office receives a 
proper invoice from the Contractor. If the designated billing office 
fails to annotate the invoice with the date of receipt at the time of 
receipt, the invoice payment due date shall be the 30th day after the 
date of the Contractor's invoice; provided the Contractor submitted a 
proper invoice

[[Page 238]]

and on disagreement exists over quantity, quality, or Contractor 
compliance with contract requirements.
    (ii) The 30th day after Government acceptance of supplies delivered 
or services performed by the Contractor.
    (3) On a final invoice, if the payment amount is subject to contract 
settlement actions, acceptance occurs on the effective date of the 
contract settlement.
    (b) The General Services Administration will issue payment on the 
due date in (a)(1) above if the Contractor complies with full cycle 
electronic commerce. Full cycle electronic commerce includes all the 
following elements:
    (1) The Contractor must receive and fulfill electronic data 
interchange (EDI) purchase orders (transaction set 850).
    (2) The Contractor must generate and submit to the Government valid 
EDI invoices (transaction set 810) of submit invoices through the GSA 
Finance Center Internet-based invoice process. Internet-based invoices 
must be submitted using procedures provided by GSA.
    (3) The Contractor's financial institution must receive and process, 
on behalf of the Contractor, EFT payments through the Automated Clearing 
House (ACH) system.
    (4) The EDI transaction sets in (b)(1) through (b)(3) above must 
adhere to implementation conventions provided by GSA.
    (c) If any of the conditions in (b) above do not occur, the 10-day 
payment due dates in (a)(1) become 30-day payment due dates.
    (d) Notwithstanding paragraph (g) of the clause at FAR 52.212-4, 
Contract Terms and Conditions--Commercial Items, if the Contractor 
submits hard-copy invoices, submit only an original invoice. No copies 
of the invoice are required.
    (e) All other provisions of the Prompt Payment Act (31 U.S.C. 3901 
et seq.) and Office of Management and Budget (OMB) Circular A-125, 
Prompt Payment, apply.

                             (End of clause)



Sec. 552.232-75  Prompt Payment

    As prescribed in 532.908 (b)(1), insert the following clause:

                        Prompt Payment (SEP 1999)

    The Government will make payments under the terms and conditions 
specified in this clause. Payment shall be considered as being made on 
the day a check is dated or an electronic funds transfer is made. All 
days referred to in this clause are calendar days, unless otherwise 
specified.
    (a) Payment due date.
    (1) Rental Payments. Rent shall be paid monthly in arrears and will 
be due on the first workday of each month, and only as provided for by 
the lease.
    (i) When the date for commencement of rent falls on the 15th day of 
the month or earlier, the initial monthly rental payment under this 
contract shall become due on the first workday of the month following 
the month in which the commencement of the rent is effective.
    (ii) When the date for commencement of rent falls after the 15th day 
of the month, the initial monthly rental payment under this contract 
shall become due on the first workday of the second month following the 
month in which the commencement of the rent is effective.
    (2) Other payments. The due date for making payments other than rent 
shall be the later of the following two events:
    (i) The 30th day after the designated billing office has received a 
proper invoice from the Contractor.
    (ii) The 30th day after Government acceptance of the work or 
service. However, if the designated billing office fails to annotate the 
invoice with the actual date of receipt, the invoice payment due date 
shall be deemed to be the 30th day after the Contractor's invoice is 
dated, provided a proper invoice is received and there is no 
disagreement over quantity, quality, or Contractor compliance with 
contract requirements.
    (b) Invoice and inspection requirements for payments other than 
rent.
    (1) The Contractor shall prepare and submit an invoice to the 
designated billing office after completion of the work. A proper invoice 
shall include the following items:
    (i) Names and address of the Contractor.
    (ii) Invoice date.
    (iii) Lease number.
    (iv) Government's order number or other authorization.
    (v) Description, price, and quantity of work or services delivered.
    (vi) Name and address of Contractor official to whom payment is to 
be sent (must be the same as that in the remittance address in the lease 
or the order).
    (vii) Name (where practicable), title, phone number, and mailing 
address of person to be notified in the event of a defective invoice.
    (2) The Government will inspect and determine the acceptability of 
the work performed or services delivered within 7 days after the receipt 
of a proper invoice or notification of completion of the work or 
services unless a different period is specified at the time the order is 
placed. If actual acceptance occurs later, for the purpose of 
determining the payment due date and calculation of interest, acceptance 
will be deemed to occur on the last day of the 7 day inspection period. 
If the work or service is rejected for failure to conform to the 
technical requirements of the contract, the 7 days will be

[[Page 239]]

counted beginning with receipt of a new invoice or notification. In 
either case, the Contractor is not entitled to any payment or interest 
unless actual acceptance by the Government occurs.
    (c) Interest Penalty. (1) An interest penalty shall be paid 
automatically by the Government, without request from the Contractor, if 
payment is not made by the due date.
    (2) The interest penalty shall be at the rate established by the 
Secretary of the Treasury under Section 12 of the Contract Disputes Act 
of 1978 (41 U.S.C. 611) that is in effect on the day after the due date. 
This rate is referred to as the ``Renegotiation Board Interest Rate,'' 
and it is published in the Federal Register semiannually on or about 
January 1 and July 1. The interest penalty shall accrue daily on the 
payment amount approved by the Government and be compounded in 30-day 
increments inclusive from the first day after the due date through the 
payment date.
    (3) Interest penalties will not continue to accrue after the filing 
of a claim for such penalties under the clause at 52.233-1, Disputes, or 
for more than 1 year. Interest rates penalties of less than $1.00 need 
not be paid.
    (4) Interest penalties are not required on payment delays due to 
disagreement between the Government and Contractor over the payment 
amount or other issues involving contract compliance or on amounts 
temporarily withheld or retained in accordance with the terms of the 
contract. Claims involving disputes, and any interest that may be 
payable, will be resolved in accordance with the clause at 52.233-1, 
Disputes.

                             (End of clause)

    Alternate I (SEP 1999). If Alternate I is used, subparagraph (a)(1) 
of the basic clause should be designated as paragraph (a) and 
subparagraph (a)(2) and paragraph (b) should be deleted. Paragraph (c) 
of the basic clause should be redesignated (b).



Sec. 552.232-76  Electronic Funds Transfer Payment.

    As prescribed in 532.908(b)(2), insert the following clause:

              Electronic Funds Transfer Payment (MAR 2000)

    (a) The Government will make payments under this lease by electronic 
funds transfer (EFT). The Lessor must, no later than 30 days before the 
first payment:
    (1) Designate a financial institution for receipt of EFT payments.
    (2) Submit this designation to the Contracting Officer or other 
Government official, as directed.
    (b) The Lessor must provide the following information:
    (1) The American Bankers Association 9-digit identifying number for 
Automated Clearing House (ACH) transfers of the financing institution 
receiving payment if the institution has access to the Federal Reserve 
Communications System.
    (2) Number of account to which funds are to be deposited.
    (3) Type of depositor account (``C'' for checking, ``S'' for 
savings).
    (4) If the Lessor is a new enrollee to the EFT system, the Lessor 
must complete and submit a ``Payment Information Form,'' SF 3881, before 
payment can be processed.
    (c) If the Lessor, during the performance of this contract, elects 
to designate a different financial institution for the receipt of any 
payment, the appropriate Government official must receive notice of such 
change and the required information specified above no later than 30 
days before the date such change is to become effective.
    (d) The documents furnishing the information required in this clause 
must be dated and contain the:
    (1) Signature, title, and telephone number of the Lessor or the 
Lessor's authorized representative.
    (2) Lessor's name.
    (3) Lease number.
    (e) Lessor's failure to properly designate a financial institution 
or to provide appropriate payee bank account information may delay 
payments of amounts otherwise properly due.

                             (End of clause)

[64 FR 37229, July 9, 1999, as amended at 65 FR 11248, Mar. 2, 2000]



Sec. 552.232-77  Payment By Governmentwide Commercial Purchase Card.

      Payment By Governmentwide Commercial Purchase Card (MAR 2000)

    (a) Definitions. ``Governmentwide commercial purchase card'' means a 
uniquely numbered credit card issued by a contractor under GSA's 
Governmentwide Contract for Fleet, Travel, and purchase Card Services to 
named individual Government employees or entities to pay for official 
Government purchases.
    ``Oral order'' means an order placed orally either in person or by 
telephone.
    (b) At the option of the Government and if agreeable to the 
Contractor, payments of ___*_ or less for oral or written orders may be 
made using the Governmentwide commercial purchase card.
    (c) The Contractor shall not process a transaction for payment 
through the credit

[[Page 240]]

card clearinghouse until the purchased supplies have been shipped or 
services performed. Unless the cardholder requests correction or 
replacement of a defective or faulty item under other contract 
requirements, the Contractor must immediately credit a cardholder's 
account for items returned as defective or faulty.
    (d) Payments made using the Governmentwide commercial purchase card 
are not eligible for any negotiated prompt payment discount. Payment 
made using a Government debit card will receive the applicable prompt 
payment discount.

                             (End of clause)

    * Enter amount not to exceed $100,000.
    Alternate I (MAR 2000). For FSS schedule solicitations and 
contracts, replace paragraph (b) of the basic clause and add paragraph 
(c) as follows. Redesignate paragraphs (c) and (d) of the basic clause 
as (d) and (e) respectively.

    (b) The Contractor must accept the Governmentwide commercial 
purchase card for payments equal to or less than the micro-purchase 
threshold (see Federal Acquisition Regulation 2.101) for oral or written 
orders under this contract.
    (c) The Contractor and the ordering agency may agree to use the 
Governmentwide commercial purchase card for dollar amounts over the 
micro-purchase threshold, and the Government encourages the Contractor 
to accept payment by the purchase card. The dollar value of a purchase 
card action must not exceed the ordering agency's established limit. If 
the Contractor will not accept payment by the purchase card for an order 
exceeding the micro-purchase threshold, the Contractor must so advise 
the ordering agency within 24 hours of receipt of the order.

[65 FR 11248, Mar. 2, 2000]



Sec. 552.232-78  Payment Information.

    As prescribed in 532.908(c), insert the following information.

                     Payment Information (JUN 2000)

    The General Services Administration (GSA) makes information on 
contract payments available electronically at http://
www.finance.gsa.gov. The Contractor may register at the site and review 
its record of payments. This site provides information only on payments 
made by GSA, not by other agencies.

                             (End of clause)

[65 FR 41379, July 5, 2000]



Sec. 552.233-70  Protests Filed Directly With the General Services 
          Administration.

    As prescribed in 533.103-72, insert the following provisions:

 Protests Filed Directly With the General Services Administration (MAR 
                                  2000)

    (a) The following definitions apply in this provision:
    ``Agency Protest Official for GSA'' means the official in the Office 
of Acquisition Policy designated to review ad decide procurement 
protests filed with GSA.
    ``Deciding official'' means the person chosen by the protester to 
decide the agency protest. The deciding official may be either the 
Contracting Officer or the Agency Protest Official.
    (b) The filing time frames in FAR 33.103(e) apply. An agency protest 
is filed when the protest complaint is received at the location the 
solicitation designates for serving protests. GSA's hours of operation 
are 8:00 a.m. to 4:30 p.m. Protests delivered after 4:30 p.m. will be 
considered received and filed the following business day.
    (c) A protest filed directly with the General Services 
Administration (GSA) must:
    (1) Indicate that it is a protest to the agency.
    (2) Be filed with the Contracting Officer.
    (3) State whether the protester chooses to have the Contracting 
Officer or the Agency Protest Official for GSA decide the protest. If 
the protest is silent on this matter, the Contracting Officer will 
decide the protest.
    (4) Indicate whether the protester prefers to make an oral 
presentation, a written presentation, or an oral presentation confirmed 
in writing, of arguments in support of the protest to the deciding 
official.
    (5) Include the information required by FAR 33.103(d)(2):
    (i) Name, address, fax number, and telephone number of the 
protester.
    (ii) Solicitation or contract number.
    (iii) Detailed statement of the legal and factual grounds for the 
protest, to include a description of resulting prejudice to the 
protester.
    (iv) Copies of relevant documents.
    (v) Request for a ruling by the agency.
    (vi) Statement as to the form of relief requested.
    (vii) All information establishing that the protester is an 
interested party for the purpose of filing a protest.
    (viii) All information establishing the timeliness of the protest 
(see paragraph (b) of this provision).
    (d) An interested party filing a protest with GSA has the choice of 
requesting either that the Contracting Officer or the Agency Protest 
Official for GSA decide the protest.

[[Page 241]]

    (e) The decision by the Agency Protest Official for GSA is an 
alternative to a decision by the Contracting Officer. The Agency Protest 
Official for GSA will not consider appeals from the Contracting 
Officer's decision on an agency protest.
    (f) The deciding Official must conduct a scheduling conference with 
the protester within three (3) days after the protest is filed. The 
scheduling conference will establish deadlines for oral or written 
arguments in support of the agency protest and for agency officials to 
present information in response to the protest issues. The deciding 
official may hear oral arguments in support of the agency protest at the 
same time as the scheduling conference, depending on availability of the 
necessary parties.
    (g) Oral conferences may take place either by telephone or in 
person. Other parties (e.g., representatives of the program office) may 
attend at the discretion of the deciding official.
    (h) The following procedures apply to information submitted in 
support of or in response to an agency protest:
    (1) The protester and the agency have only one opportunity to 
support or explain the substance of the protest (either orally, in 
writing, or orally confirmed in writing).
    (2) GSA procedures do not provide for any discovery.
    (3) The deciding official has discretion to request additional 
information from either the agency or the protester. However, the 
deciding official will normally decide protests on the basis of 
information provided by the protester and the agency.
    (4) Except as provided in paragraph (5)(ii) below, the parties are 
encouraged, but not required, to exchange information submitted to the 
Agency Protest Official for GSA.
    (5) If the agency makes a written response to the protest, the 
following filling requirements apply unless the deciding official 
approves other arrangements:
    (i) The agency must file its response to the protest with the 
deciding official within five (5) days after the filing of the protest.
    (ii) The agency must also provide the protester with a copy of the 
response on the same day it files the response with the deciding 
official. If the agency believes it needs to redact or withhold any 
information in the response from the protester, it must obtain the 
approval of the deciding official.
    (i) The deciding official will resolve the protest through informal 
presentations or meetings to the maximum extent practicable.
    (j) An interested party may represent itself or be represented by 
legal counsel. GSA will not reimburse the party for any legal fees 
related to the agency protest.
    (k) GSA will stay award or suspend contract performance in 
accordance with FAR 33.103(f). The stay or suspension, unless over-
ridden, remains in effect until the protest is decided, dismissed, or 
withdrawn.
    (l) The deciding official will make a best effort to issue a 
decision on the protest within twenty-eight (28) days after the filing 
date. The decision may be oral or written. If the decision is 
communicated orally to the protester, the deciding official will confirm 
in writing within three (3) days after the decision.
    (m) GSA may dismiss or stay proceedings on an agency protest if a 
protest on the same or similar basis is filed with a protest forum 
outside of GSA.

                           (End of provision)

[64 FR 37229, July 9, 1999, as amended at 65 FR 11248, Mar. 2, 2000]



Sec. 552.236-70  Definitions.

    As prescribed in 536.570-1, insert the following clause:

                         Definitions (APR 1984)

    The terms ``Administration'' and ``Service'' as used in this 
contract shall mean the General Services Administration (GSA) and the 
Public Buildings Service (PBS), respectively.

                             (End of clause)



Sec. 552.236-71  Authorities and Limitations.

    As prescribed in 536.570-2, insert the following clause:

                 Authorities and Limitations (APR 1984)

    (a) All work shall be performed under the general direction of the 
Contracting Officer, who alone shall have the power to bind the 
Government and to exercise the rights, responsibilities, authorities and 
functions vested in him by the contract documents, except that he shall 
have the right to designate authorized representatives to act for him. 
Wherever any provision in this contract specifies an individual (such 
as, but not limited to, Construction Engineer, Resident Engineer, 
Inspector or Custodian) or organization, whether governmental or 
private, to perform any act on behalf of or in the interests of the 
Government, that individual or organization shall be deemed to be the 
Contracting Officer's authorized representative under this contract but 
only to the extent so specified. The Contracting Officer may, at any 
time during the performance of this contract, vest in any such 
authorized representatives additional power and authority to act for him 
or designate additional representatives, specifying the extent of their 
authority to act for him; a copy of each document

[[Page 242]]

vesting additional authority in an authorized representative or 
designating an additional authorized representative shall be furnished 
to the Contractor.
    (b) The Contractor shall perform the contract in accordance with any 
order (including but not limited to instruction, direction, 
interpretation, or determination) issued by an authorized representative 
in accordance with his authority to act for the Contracting Officer; but 
the Contractor assumes all the risk and consequences of performing the 
contract in accordance with any order (including but not limited to 
instruction, direction, interpretation, or determination) of anyone not 
authorized to issue such order.

                             (End of clause)



Sec. 552.236-72  Specialist.

    As prescribed in 536.570-3, insert the following clause:

                          Specialist (APR 1984)

    The term ``Specialist,'' as used in the contract specification, 
shall mean an individual or firm of established reputation (or, if newly 
organized, whose personnel have previously established a reputation in 
the same field), which is regularly engaged in, and which maintains a 
regular force of workmen skilled in either (as applicable) manufacturing 
or fabricating items required by the contract, installing items required 
by the contract, or otherwise performing work required by the contract. 
Where the contract specification requires installation by a specialist, 
that term shall also be deemed to mean either the manufacturer of the 
item, an individual or firm licensed by the manufacturer, or an 
individual or firm who will perform the work under the manufacturer's 
direct supervision.

                             (End of clause)



Sec. 552.236-73  Basis of Award--Construction Contract.

    As prescribed in 536.570-4, insert the following provision or the 
appropriate Alternate:

            Basis of Award--Construction Contract (APR 1985)

    (a) The low bidder for purposes of award is the responsible bidder 
offering the lowest price for the base bid (consisting of the lump sum 
bid and any associated unit price bids extended by the applicable number 
of units shown on the bid form). See Standard Form 1442, Solicitation, 
Offer, and Award and the provision entitled ``Contract Award--Sealed 
Bidding.''
    (b) A bid may be rejected as nonresponsive if the bid is materially 
unbalanced as to bid prices. A bid is unbalanced when the bid is based 
on prices significantly less than cost for some work and significantly 
overstated for other work.

                           (End of provision)

    Alternate I (APR 1985). if the solicitation includes a base bid and 
options, the Contracting Officer shall delete paragraph (a) of the basic 
provision and insert paragraph (a) substantially as follows:

    (a) The low bidder for purposes of award is the responsible bidder 
offering the lowest aggregate price for (1) the base bid (consisting of 
the lump sum bid and any associated unit price bids extended by the 
applicable number of units shown on the bid form) plus (2) all options 
designated to be evaluated. The evaluation of options will not obligate 
the Government to exercise the options. See Standard Form 1442, 
Solicitation, Offer, and Award and the provision entitled ``Contract 
Award--Sealed Bidding.''
    Alternate II (APR 1985). If the solicitation includes a base bid and 
alternates, the Contracting Officer shall delete paragraph (a) of the 
basic provision and insert paragraphs (a), (c), and (d) substantially as 
follows:

    (a) The low bidder for purposes of award is the responsible bidder 
offering the lowest aggregate price for (1) the base bid (consisting of 
the lump sum bid and any associated unit price bids extended by the 
applicable number of units shown on the bid form) plus (2) those 
alternates in the order of priority listed in the solicitation that 
provide the most features of work within the funds available at bid 
opening. See the provision entitled ``Contract Award--Sealed Bidding.''
    (c) Alternates will be added to the base bid in the order listed in 
the solicitation (see Standard Form 1442, Solicitation, Offer, and 
Award). If the addition of an alternate would make all bids exceed the 
funds available at bid opening, that alternate shall be skipped and the 
next subsequent alternate in a lower amount shall be added, provided 
that the aggregate of base bid and the selected alternates do not exceed 
the funds available at bid opening. For example, when the amount 
available is $100,000 and a bidder's base bid is $85,000, with its 
separate bids on four successive alternatives being $10,000, $8,000, 
$6,000, and $4,000, the aggregate amount of the bid for purposes of 
selecting the alternates would be $99,000 (base bid plus the first and 
four alternates). The second and third alternates are skipped because 
each of them would cause the aggregate of the base bid

[[Page 243]]

and alternates to exceed the $100,000 amount available when considered 
with the first alternate. All bids shall be evaluated on the basis of 
the same alternates.
    (d) After the low bidder has been determined in accordance with 
paragraph (a), an award may be made to that low bidder on the base bid, 
plus any combination of alternates for which funds are available at the 
time of award, but only if the award amount does not exceed the amount 
offered by any other responsible bidder. If the base bid plus the 
proposed combination of alternates exceed the amount offered by any 
other responsible bidder for thesame combination of alternates, the 
award cannot be made on that combination of alternates.

    Alternate III (APR 1985). If the solicitation includes a base bid, 
alternates, and options, the Contracting Officer shall delete paragraph 
(a) of the basic provision and insert paragraphs (a), (c), and (d) 
substantially as follows:

    (a) The low bidder for purposes of award is the responsible bidder 
offering the lowest aggregate price for (1) the base bid (consisting of 
the lump sum bid and any associated unit price bids extended by the 
applicable number of units shown on the bid form) plus (2) those 
alternates in the order of priority listed in the solicitation that 
provide the most features of work within the funds available at bid 
opening plus (3) all options designated to be evaluated except those 
options associated with alternates which are skipped during the 
selection process outlined in paragraph (c) below. The evaluation of 
options will not obligate the Government to exercise the options. See 
the provision entitled ``Contract Award--Sealed Bidding.''
    (c) Alternates will be added to the base bid in the order listed in 
the solicitation (see Standard Form 1442, Solicitation, Offer, or 
Award). If the addition of an alternate would make all bids exceed the 
funds available at bid opening, that alternate shall be skipped and the 
next subsequent alternate in a lower amount shall be added, provided 
that the aggregate of base bid and the selected alternates do not exceed 
the funds available at bid opening. For example, when the amount 
available is $100,000 and a bidder's base bid is $85,000, with its 
separate bids on four successive alternates being $10,000, $8,000, 
$6,000, and $4,000, the aggregate amount of the bid for purposes of 
selecting the alternates would be $99,000 (base bid plus the first and 
fourth alternates). The second and third alternates are skipped because 
each of them would cause the aggregate of the base bid and alternates to 
exceed the $100,000 amount available when considered with the first 
alternate. All bids shall be evaluated on the basis of the same 
alternates.
    (d) After the low bidder has been determined in accordance with 
paragraph (a), award may be made to that low bidder on the base bid and 
evaluated options plus any combination of alternates for which funds are 
available at the time of award, but only if that low bidder is still low 
on the sum thereof plus any previously unevaluated options designated to 
be evaluated which are associated with proposed alternates that were 
skipped during the selection under paragraph (c). If that low bidder is 
not still low, award cannot be made on the proposed combination of 
alternates.



Sec. 552.236-74  Working Hours.

    As prescribed in 536.570-5, insert the following clause:

                        Working Hours (APR 1984)

    (a) It is contemplated that all work will be performed during the 
customary working hours of the trades involved unless otherwise 
specified in this contract. Work performed by the Contractor at his own 
volition outside such customary working hours shall be at no additional 
expense to the Government.
    (b) Any requests received by the Contractor from occupants of 
existing buildings to change the hours of work shall be referred to the 
Contracting Officer for determination.

                             (End of clause)



Sec. 552.236-75  Use of Premises.

    As prescribed in 536.570-6, insert the following clause:

                       Use of Premises (APR 1984)

    (a) If the premises are occupied, the Contractor, his 
subcontractors, and their employees shall comply with the regulations 
governing access to, operation of, and conduct while in or on the 
premises and shall perform the work required under this contract in such 
a manner as not to unreasonably interrupt or interfere with the conduct 
of Government business.
    (b) Any request received by the Contractor from occupants of 
existing buildings to change the sequence of work shall be referred to 
the Contracting Officer for determination.
    (c) If the premises are occupied, the Contractor, his subcontractors 
and their employees shall not have access to or be admitted into any 
building outside the scope of this contract except with official 
permission.

                             (End of clause)



Sec. 552.236-76  Measurements.

    As prescribed in 536.570-7, insert the following clause:

[[Page 244]]

                         Measurements (APR 1984)

    All dimensions shown of existing work and all dimensions required 
for work that is to connect with work now in place, shall be verified by 
the Contractor by actual measurement of the existing work. Any 
discrepancies between the contract requirements and the existing 
conditions shall be referred to the Contracting Officer before any work 
affected thereby has been performed.

                             (End of clause)



Sec. 552.236-77  Specifications and Drawings

    As prescribed in 536.570-8, insert the following clause:

                 Specifications and Drawings (SEP 1999)

    The requirements of the clause entitled ``Specifications and 
Drawings for Construction'' at FAR 52.236-21, are supplemented as 
follows:
    (a) In case of difference between small and large-scale drawings, 
the large-scale drawings shall govern. Schedules on any contract drawing 
shall take precedence over conflicting information on that or any other 
contract drawing. On any of the drawings where a portion of the work is 
detailed or drawn out and the remainder is shown in outline, the parts 
detailed or drawn out shall apply also to all other like portions of the 
work.
    (b) Where the word ``similar'' occurs on the drawings, it shall have 
a general meaning and not be interpreted as being identical, and all 
details shall be worked out in relation to their location and their 
connection with other parts of the work.
    (c) Standard Details or Specification Drawings are applicable when 
listed, bound with the specifications, noted on the drawings or 
referenced elsewhere in the specifications. Where the notes on the 
drawings indicate modifications, such modifications shall govern.
    (d) In case of difference between Standard Details or Specification 
Drawings and the specifications, the specifications will govern. In case 
of difference between the Standard Details or Specification Drawings and 
their drawings prepared specifically for this contract, the later shall 
govern.

                             (End of clause)



Sec. 552.236-78  Shop Drawings, Coordination Drawings, and Schedules.

    As prescribed in 536.570-9, insert the following clause:

     Shop Drawings, Coordination Drawings, and Schedules (SEP 1999)

    The requirements, of the clause entitled ``Specifications and 
Drawings for Construction'' at FAR 52.236-21, are supplemented as 
follows:
    (a) The Contractor shall submit shop drawings, coordination 
drawings, and schedules for approval as required by the specifications 
or requested by the Contracting Officer as follows:
    (b) Show drawings shall include fabrication, erection and setting 
drawings, schedule drawings, manufacturers' scale drawings, wriring and 
control diagrams, cuts or entire catalogs, pamphlets, descriptive 
literature, and performance and test data.
    (c) Drawings and schedules, other than catalogs, pamphlets and 
similar printed material, shall be submitted in reproducible form with 
two prints made by a process approved by the Contracting Officer. Upon 
approval, the reproducible form will be returned to the Contractor who 
shall then furnish the number of additional prints, not to exceed 10, 
required by the specifications. The Contractor shall submit shop 
drawings in catalog, pamphlet and similar printed form in a minimum of 
four copies plus as many additional copies as the Contractor may desire 
or need for his use or use by subcontractors.
    (d) Before submitting shop drawings on the mechanical and electrical 
work, the Contractor shall submit and obtain the Contracting Officer's 
approval of such lists of mechanical and electrical equipment and 
materials as may be required by the specifications.
    (e) Each shop drawing or coordination drawing shall have a blank 
area 5 by 5 inches, located adjacent to the title block. The title block 
shall display the following:

Number and title of drawing
Date of drawing or revision
Name of project building or facility
Name of Contractor and (if appropriate) name of subcontractor submitting 
drawing
Clear identify of contents and location on the work
Project title and contract number

    (f) Unless otherwise provided in this contract, or otherwise 
directed by the Contracting Officer, shop drawings, coordination 
drawings and schedules shall be submitted to the Contracting Officer, 
with a letter in triplicate, sufficiently in advance of construction 
requirements to permit no less than 10 working days for checking and 
appropriate action.
    (g) Approval of drawings and schedules will be general and shall not 
be construed as permitting any departure from the contract requirements, 
or as approving departures from full-size details furnished by the 
Contracting Officer.


[[Page 245]]



                             (End of clause)



Sec. 552.236-79  Samples.

    As prescribed in 536.570-10, insert the following clause:

                           Samples (APR 1984)

    (a) After the award of the contract, the Contractor shall furnish 
for the approval of the Contracting Officer samples required by the 
specifications or by the Contracting Officer. Samples shall be delivered 
to the Contracting Officer or to the Architect as specified or as 
directed. The Contractor shall prepay all shipping charges on samples. 
Materials or equipment for which samples are required shall not be used 
in the work until approved in writing by the Contracting Officer.
    (b) Each sample shall have a label indicating:
    (1) Name of project building or facility, project title and contract 
number.
    (2) Name of Contractor and, if appropriate, name of subcontractor.
    (3) Identification of material or equipment with specification 
requirement.
    (4) Place of origin.
    (5) Name of producer and brand (if any).
    Samples of finished materials shall have additional markings that 
will identify them under the finish schedules.
    (c) The Contractor shall mail under separate cover a letter in 
triplicate submitting each shipment of samples and containing the 
information required in paragraph (b) of this clause. He shall enclose a 
copy of this letter with the shipment and send a copy to the Government 
representative on the project. Approval of a sample shall be only for 
the characteristics or use named in such approval and shall not be 
construed to change or modify any contract requirement. Substitutions 
will not be permitted unless they are approved in writing by the 
Contracting Officer.
    (d) Approved samples not destroyed in testing will be sent to the 
Government representative at the project. Approved samples of hardware 
in good condition will be marked for identification and may be used in 
the work. Materials and equipment, incorporated in the work shall match 
the approved samples. Other samples not destroyed in testing or not 
approved will be returned to the Contractor at his expense if so 
requested at time of submission.
    (e) Failure of any material to pass the specified tests will be 
sufficient cause for refusal to consider, under this contract, any 
further samples of the same brand or make of that material or equipment 
which previously has proved unsatisfactory in service.
    (f) Samples of various materials or equipment delivered on the site 
or in place may be taken by the Government representative for testing. 
Samples failing to meet contract requirements, or there shall be a 
proper adjustment of the contract price as determined by the Contracting 
Officer.
    (g) Unless otherwise specified, when tests are required only one 
test of each sample proposed for use will be made at the expense of the 
Government. Samples which do not meet specification requirements will be 
rejected. Testing of additional samples will be made by the Government 
at the expense of the Contractor.

                             (End of clause)



Sec. 552.236-80  Heat.

    As prescribed in 536.570-11, insert the following clause:

                             Heat (APR 1984)

    Unless otherwise specified or unless already provided by the 
Government the Contractor shall;
    (a) Provide heat, as necessary to protect all work, materials, and 
equipment against injury from dampness and cold;
    (b) Protect, cover and/or heat as may be necessary, to provide and 
maintain a temperature of not less than 50 degrees Fahrenheit (1) in the 
concrete during the placing, setting and curing of concrete, and (2) in 
the plaster during the application, setting and curing of plaster; and
    (c) Provide heat as necessary in the area where work is to be done 
to provide the minimum temperature recommended by the supplier or 
manufacturer of the material, but in no case less than 50 degrees 
Fahrenheit, for a period beginning 10 days before placing or interior 
finishes and finish materials and continuing until completion or 
beneficial occupancy of the area, whichever is earlier.

                             (End of clause)



Sec. 552.236-81  Use of Equipment by the Government.

    As prescribed in 536.570-12, insert the following clause:

              Use of Equipment by the Government (APR 1984)

    (a) The Government may take over and operate, with Government 
employees, such equipment as is necessary for heating or cooling such 
areas of the building as require the service, as soon as the 
installation is sufficiently complete.
    (b) The Contracting Officer will advise the Contractor by letter, 
prior to the use of equipment, which items of equipment will be 
operated, and the date and time such operation will begin.
    (c) Government operation of equipment will not relieve the 
Contractor of the one-

[[Page 246]]

year guarantee on materials and workmanship elsewhere provided for in 
this contract.
    (d) The guarantee period, elsewhere provided for in this contact, 
for each piece of equipment shall be in accordance with the 
``Guarantees'' clause of this contract.

                             (End of clause)



Sec. 552.236-82  Subcontracts.

    As prescribed in 536.570-13, insert the following clause:

                         Subcontracts (APR 1984)

    (a) Nothing contained in the contract shall be construed as creating 
any contractual relationship between any subcontractor and the 
Government. The divisions or sections of the specifications are not 
intended to control the Contractor in dividing the work among 
subcontractors, or to limit the work performed by any trade.
    (b) The Contractor shall be responsible to the Government for acts 
and omissions of his own employees and of subcontractors and their 
employees. He shall also be responsible for the coordination of the work 
of the trades, subcontractors and suppliers.
    (c) The Government will not undertake to settle any differences 
between or among the Contractor, subcontractors, or suppliers.

                             (End of clause)



Sec. 552.236-83  Requirement for a Project Labor Agreement.

    As prescribed in 536.570-14, insert a clause substantially the same 
as the following:

          Requirement for a Project Labor Agreement (SEP 1999)

    (a) Definition. ``Project Labor Agreement'' (PLA) means an agreement 
between the contractor, subcontractors, and the union(s) representing 
workers. Under a PLA, the contractor and subcontractors on a project and 
the union(s) agree on terms and conditions of employment for the 
project, establishing a framework for labor-management cooperation to 
advance the Government's procurement interest in cost, efficiency, and 
quality.
    (b) The Contractor shall, after contract award, enter into a PLA for 
performance of [Insert project or contract name]. The PLA binds the 
Contractor and subcontractors of whatever tier engaged in onsite 
construction work. The PLA shall include all the following terms:
    (1) Guarantees against strikes, lockouts, and similar work 
disruptions.
    (2) Effective, prompt and mutually binding procedures for resolving 
labor disputes arising during the project.
    (3) Other mechanisms for labor-management cooperation on matters of 
mutual interest and concern, including productivity, quality of work, 
safety, and health.
    (4) The PLA shall fully conform to all applicable statutes, 
regulations, and Executive Orders.
    (c) Any PLA reached under this clause shall not change the terms of 
this contract or provide for any pricing adjustment by the Government.
    (d) The Government shall not participate in the negotiations of any 
PLA.
    (e) Nothing in this clause precludes contractors or subcontractors 
from competing for contracts or subcontracts on this project without 
discrimination based on union or non-union status.

                             (End of clause)



Sec. 552.237-70  Qualifications of Offerors.

    As prescribed in 537.110(a), insert the following provision:

                  Qualifications of Offerors (MAY 1989)

    (a) Offers will be considered only from responsible organizations or 
individuals now or recently engaged in the performance of building 
service contracts comparable to those described in this solicitation. In 
order to determine an Offeror's qualifications, the Offeror may be 
requested to furnish a narrative statement listing comparable contracts 
which it has performed; a general history of its operating organization; 
and its complete experience. An Offeror may also be required to furnish 
a statement of its financial resources; show that it has the ability to 
maintain a staff of regular employees adequate to ensure continuous 
performance of the work; and, demonstrate that its equipment and/or 
plant capacity for the work contemplated is sufficient, adequate, and 
suitable.
    (b) Competency in performing comparable building service contracts, 
demonstration of acceptable financial resources, personnel staffing, 
plant, equipment, and supply sources will be considered in determining 
whether an Offeror is responsible.
    (c) Prospective Offerors are advised that in evaluating these areas 
involving any small business concern(s), any negative determinations are 
subject to the Certificate of Competency procedures set forth in the 
Federal Acquisition Regulation.


[[Page 247]]



                           (End of provision)



Sec. 552.237-71  Qualifications of Employees.

    As prescribed in 537.110(b), insert the following clause:

                 Qualifications of Employees (MAY 1989)

    (a) The contracting officer or a designated representative may 
require the Contractor to remove any employee(s) from GSA controlled 
buildings or other real property should it be determined that the 
individual(s) is either unsuitable for security reasons or otherwise 
unfit to work on GSA controlled property.
    (b) The Contractor shall fill out and cause all of its employees 
performing work on the contract work to fill out, for submission to the 
Government, such forms as may be necessary for security or other 
reasons. Upon request of the Contracting Officer, the Contractor and its 
employees shall be fingerprinted.
    (c) Each employee of the Contractor shall be a citizen of the United 
States of America, or an alien who has been lawfully admitted for 
permanent residence as evidenced by Alien Registration Receipt Card Form 
I-151, or, who presents other evidence from the Immigration and 
Naturalization Service that employment will not affect his immigration 
status.

                             (End of clause)



Sec. 552.237-72  Prohibition Regarding ``Quasi-Military Armed Forces.''

    As prescribed in 537.110(c), insert the following clause:

    Prohibition Regarding ``Quasi-Military Armed Forces'' (SEP 1999)

    The Contractor must not, during the term of this contract, offer for 
hire ``Quasi-Military Armed Forces'' within the meaning of the court 
decision in United States ex. rel. Weinberger v. Equifax, 557 F.2d 456 
(5th Cir. 1977).

                             (End of clause)



Sec. 552.237-73  Restriction on Disclosure of Information.

    As prescribed in 537.270, insert the following clause:

           Restriction on Disclosure of Information (SEP 1999)

    (a) The Contractor shall, in the performance of this contract, keep 
all information contained in source documents or other media furnished 
by the Government in the strictest confidence. The Contractor shall not 
publish or otherwise divulge such information in whole or in part, in 
any manner or form, nor authorize or permit others to do so. The 
Contractor shall take such reasonable measures as are necessary to 
restrict access to such information, while in the Contractor's 
possession, to those employees needing such information to perform the 
work provided herein, i.e., on a ``need to know'' basis. The Contractor 
shall immediately notify, in writing, the Contracting Officer in the 
event that the Contractor determines or has reason to suspect a breach 
of this requirement.
    (b) The Contractor shall not disclose any information concerning the 
work under this contract to any person or individual unless the 
Contractor obtains prior written approval from the Contracting Officer.
    (c) The Contractor shall insert the substance of this clause in any 
consultant agreement or subcontract under this contract.
    (d) Any unauthorized disclosure of information may result in 
termination of this contract for cause.

                             (End of clause)



Sec. 552.238-70  Identification of Electronic Office Equipment Providing 
          Accessibility for the Handicapped.

    As prescribed in 538.273(a)(1), insert the following clause:

 Identification of Electronic Office Equipment Providing Accessibility 
                     for the Handicapped (SEP 1991)

    (a) Definitions. ``Electronic office equipment accessiblity'' means 
the application/configuration of electronic office equipment (includes 
hardware, software and firmware) in a manner that accommodates the 
functional limitations of individuals with disabilities (i.e., 
handicapped individuals) so as to promote productivity and provide 
access to work related and/or public information resources.
    ``Handicapped individuals'' mean qualified individuals with 
impairments as cited in 29 CFR 1613.702(f) who can benefit from 
electronic office equipment accessibility.
    ``Special peripheral'' means a special needs aid that provides 
access to electronic equipment that is otherwise inaccessible to a 
handicapped individual.
    (b) The offeror is encouraged to identify in its offer, and include 
in any commercial catalogs and pricelists accepted by the Contracting 
Officer, office equipment, including any special peripheral, that will 
facilitate electronic office equipment accessibility for handicapped 
individuals. Identification should include the type of disability 
accommodated and how the users with that disability would be helped.


[[Page 248]]



                             (End of clause)



Sec. 552.238-71  Submission and Distribution of Authorized FSS Schedule 
          Pricelists.

    As prescribed in 538.273(a)(2), insert the following clause:

 Submission and Distribution of Authorized FSS Schedule Pricelists (SEP 
                                  1999)

    (a) Definition. For the purposes of this clause, the Mailing List is 
[Contracting officer shall insert either: ``the list of addressees 
provided to the Contractor by the Contracting Officer'' or ``the 
Contractor's listing of its Federal Government customers''].
    (b) The Contracting Officer will return one copy of the Authorize 
FSS Schedule Pricelist to the Contractor with the notification of 
contract award.
    (c)(1) The Contractor shall provide to the GSA Contracting Officer:
    (i) Two paper copies of Authorized FSS Schedule Pricelist; and
    (ii) The Authorized FSS Schedule Pricelist on a common-use 
electronic medium.
    The Contracting Officer will provide detailed instructions for the 
electronic submission with the award notification. Some structured data 
entry in a prescribed format may be required.
    (2) The Contractor shall provide to each addressee on the mailing 
list either:
    (i) One paper copy of the Authorized FSS Schedule Price List; or
    (ii) A self-addressed, postage-paid envelope or postcard to be 
returned by addressee that want to receive a paper copy of the 
pricelist. The Contractor shall distribute price lists within 20 
calendar days after receipt of returned requests.
    (3) The Contractor shall advise each addressee of the availability 
of pricelist information through the on-line Multiple Award Schedule 
electronic data base.
    (d) The Contractor shall make all of the distributions required in 
paragraph (c) at least 15 calendar days before the beginning of the 
contract period, or within 30 calendar days after receipt of the 
Contracting Officer's approval for printing, whichever is later.
    (e) During the period of the contract, the Contractor shall provide 
one copy of its Authorized FSS Schedule Pricelist to any authorized 
schedule user, upon request. Use of the mailing list for any other 
purpose is not authorized.

                             (End of clause)



Sec. 552.238-72  Identification of Energy-Efficient Office Equipment and 
          Supplies Containing Recovered Materials or Other Environmental 
          Attributes.

    As prescribed in 538.273(a)(3), insert the following clause:

    Identification of Energy-Efficient Office Equipment and Supplies 
 Containing Recovered Materials or Other Environmental Attributes (SEP 
                                  1999)

    (a) Definitions. ``Energy-efficient office equipment,'' as used in 
this clause, means office equipment that, in representative use, 
provides equivalent or better performance and value to users, but uses 
significantly less energy than most functionally equivalent models.
    ``Recovered materials,'' as used in this clause, means waste 
material and by-products which have been recovered or diverted from 
solid waste, but such term does not include those materials and by-
products generated from, and commonly reused, within an original 
manufacturing process (42 U.S.C. 6903(19)). For paper, it also includes 
postconsumer materials, and manufacturing and certain other wastes. (42 
U.S.C. 6962(h)).
    ``Remanufactured products,'' as used in this clause, means equipment 
or parts that have been factory remanufactured or rebuilt to meet new 
equipment or part performance specifications and have had no use 
subsequent to their remanufacture.
    (b) The offeror shall identify in its offer and include in any 
commercial catalogs and pricelists and any resultant Government catalogs 
or pricelists submitted to the Contracting Officer, energy-efficient 
office equipment and supplies that contain recovered material, 
remanufactured products, or other environmental attributes. Examples of 
energy-efficient office equipment are microcomputers and associated 
equipment that meet the requirements of the Environmental Protection 
Agency's (EPA's) Energy Star Computers Program. Supplies that contain 
recovered materials and other environmental attributes include, but are 
not limited to, products identified in EPA procurement guidelines (40 
CFR Subchapter I) and products that are either degradable, ozone safe, 
recyclable, contain low volatile organic content compounds, contribute 
to source reduction, or otherwise are designed or manufactured to 
achieve environmental improvement. For example, an offeror can identify 
products that are safe or safer alternatives for more toxic or hazardous 
products and

[[Page 249]]

products that can be substituted for ones manufactured with toxic or 
hazardous materials. Such supplies shall satisfy the guidance contained 
in 16 CFR Part 260, Guides for the Use of Environmental Marketing 
Claims.
    (c) An offeror, in identifying an item with an environmental 
attribute, shall possess evidence or rely upon a reasonable basis to 
substantiate the claim (see 16 CFR 260.5). The Government will accept an 
offeror's claim of an item's environmental attribute on the basis of--
    (1) Participation in a Federal agency sponsored program, e.g., EPA's 
Energy Star Computer program;
    (2) Verification by an independent organization that specializes in 
certifying such claims; or
    (3) Possession of competent and reliable evidence. For any test, 
analysis, research, study or other evidence to be ``competent and 
reliable,'' it must have been conducted and evaluated in an objective 
manner by persons qualified to do so, using procedures generally 
accepted in the profession to yield accurate and reliable results.

                             (End of clause)



Sec. 552.238-73  Cancellation.

    As prescribed in 538.273(a)(4), insert the following clause:

                         Cancellation (SEP 1999)

    Either party may cancel this contract in whole or in part by 
providing written notice. The cancellation will take effect 30 calendar 
days after the other party receives the notice of cancellation. If the 
Contractor elects to cancel this contract, the Government will not 
reimburse the minimum guarantee.

                             (End of clause)



Sec. 552.238-74  Contractor's Report of Sales.

    As prescribed in 538.273(b)(1), insert the following clause:

                 Contractor's Report of Sales (SEP 1999)

    (a) The Contractor must report the quarterly dollar value (in U.S. 
dollars and rounded to the nearest whole dollar) of all sales under this 
contract by calendar quarter (i.e., January-March, April-June, July-
September, and October-December). The dollar value of a sale is the 
price paid by the schedule user for products and services on a schedule 
contract task or delivery order, as recorded by the Contractor. The 
reported contract sales value must include the industrial funding fee 
(see Clause 552.238-76).
    (b) The Contractor must report the quarterly dollar value of sales 
on electronic GSA Form 72A, Contractor's Report of Sales, to the FSS 
Vendor Support Center (VSC) Website at Internet, http://VSC.gsa.gov. The 
Contractor must report sales separately for each National Stock Number 
(NSN), Special Item Number (SIN), or subitem. If no sales occur, the 
Contractor must show zero on the report for each separate NSN, SIN, or 
subitem.
    (c) The Contractor must register with the VSC before using the 
automated reporting system. To register, the Contractor (or its 
authorized representative) must call the VSC at (703) 305-6235 and 
provide the necessary information regarding the company, contact 
name(s), and telephone number(s). The VSC will then issue a 72A specific 
password and provide other information needed to access the reporting 
system. Instructions for electronic reporting are available at the VSC 
Website or by calling the above phone number.
    (d) The Contractor must convert the total value of sales made in 
foreign currency to U.S. dollars using the ``Treasury Reporting Rates of 
Exchange,'' issued by the U.S. Department of Treasury, Financial 
Management Service. The Contractor must use the issue of the Treasury 
report in effect on the last day of the calendar quarter. The report is 
available from: Department of the Treasury, Financial Management 
Service, International Funds Branch, 3700 East-West Highway, PGCII, Room 
5A19, Hyattsville, MD 20782, Telephone: (202) 874-7994, Internet: http:/
/www.fms.treas.gov/intn.html.
    (e) The report is due 30 days following the completion of the 
reporting period. The Contractor must also provide a close-out report 
within 120 days after the expiration of the contract. The contract 
expires upon physical completion of the last, outstanding task or 
delivery order of the contract. The close-out report must cover all 
sales not shown in the final quarterly report and reconcile all errors 
and credits. If the Contractor reported all contract sales and 
reconciled all errors and credits on the final quarterly report, then 
show zero sales in the close-out report.

                             (End of clause)



Sec. 552.238-75  Price Reductions.

    As prescribed in 538.273(b)(2), insert the following clause:

                       Price Reductions (SEP 1999)

    (a) Before award of a contract, the Contracting Officer and the 
Offeror will agree upon (1) the customer (or category of customers) 
which will be the basis of award, and (2) the Government's price or 
discount relationship to the identified customer (or category of 
customers). This relationship shall

[[Page 250]]

be maintained through out the contract period. Any change in the 
Contractor's commercial pricing or discount arrangement applicable to 
the identified customer (or category of customers) which disturbs this 
relationship shall constitute a price reduction.
    (b) During the contract period, the Contractor shall report to the 
Contracting Officer all price reductions to the customer (or category of 
customers) that was the basis of award. The Contractor's report shall 
include an explanation of the conditions under which the reductions were 
made.
    (c)(1) A price reduction shall apply to purchases under this 
contract if, after the date negotiations conclude, the Contractor--
    (i) Revises the commercial catalog, pricelist, schedule or other 
document upon which contract award was predicated to reduce prices;
    (ii) Grants more favorable discounts or terms and conditions than 
those contained in the commercial catalog, pricelist, schedule or other 
documents upon which contract award was predicated; or
    (iii) Grants special discounts to the customer (or category of 
customers) that formed the basis of award, and the change disturbs the 
price/discount relationship of the Government to the customer (or 
category of customers) that was the basis of award.
    (2) The Contractor shall offer the price reduction to the Government 
with the same effective date, and for the same time period, as extended 
to the commercial customer (or category of customers).
    (d) There shall be no price reduction for sales--
    (1) To commercial customers under firm, fixed-price definite 
quantity contracts with specified delivery in excess of the maximum 
order threshold specified in this contract;
    (2) To Federal agencies; or
    (3) Caused by an error in quotation or billing, provided adequate 
documentation is furnished by the Contractor to the Contracting Officer.
    (e) The Contractor may offer the Contracting Officer a voluntary 
Governmentwide price reduction at any time during the contract period.
    (f) The Contractor shall notify the Contracting Officer of any price 
reduction subject to this clause as soon as possible, but not later than 
15 calendar days after its effective date.
    (g) The contractor will be modified to reflect any price reduction 
which becomes applicable in accordance with this clause.

                             (End of clause)



Sec. 552.238-76  Industrial Funding Fee.

    As prescribed in 538.273(b)(3), insert the following clause:

                    Industrial Funding Fee (SEP 1999)

    (a) The Contractor must pay the Federal Supply Service, GSA, an 
industrial funding fee (IFF). The Contractor must remit the IFF in U.S. 
dollars within 30 days after the end of each quarterly reporting period 
as established in clause 552.238-74, Contractor's Report of Sales. The 
IFF equals ____*____ of total quarterly sales reported. The IFF 
reimburses the GSA Federal Supply Service for the costs of operating the 
Federal Supply Schedules Program and recoups its operating costs from 
ordering activities. Offerors must include the IFF in their prices. The 
fee is included in the award price(s) and reflected in the total amount 
charged to ordering activities.
    (b) The Contractor must remit any monies due as a result of the 
close-out report required by Clause 552.238-74 at the time the close-out 
report is submitted to GSA.
    (c) The Contractor must pay the IFF amount due by check, or 
electronic funds transfer through the Automated Clearing House (ACH), to 
the ``General Services Administration.'' If the payment involves 
multiple special item numbers or contracts, the Contractor may 
consolidate the IFFs into one payment. To ensure that the payment is 
credited properly, the Contractor must identify the check or electronic 
transmission as an ``Industrial Funding Fee'' and include the following 
information: contract number(s); report amount(s); and report period(s). 
If the Contractor makes payment by check, provide this information on 
either the check, check stub, or other remittance material.
    (1) If paying the IFF by check, the Contractor must forward the 
check to the following address: General Services Administration, 
Accounts Receivable Branch, P.O. Box 70500, Chicago, IL 60673-0500.
    (2) If paying by electronic funds transfer through the ACH, the 
Contractor must call GSA, Financial Information Control Branch, 
Receivables, Collections and Sales Section (6BCDR) at [Contracting 
Officer to insert phone number] to make arrangements.
    (d) If the full amount of the IFF is not paid within 30 calendar 
days after the end of the applicable reporting period, it constitutes a 
contract debt to the United States Government under the terms of FAR 
32.6. The Government may exercise all rights under the Debt Collection 
Act of 1982, including withholding or setting off payments and interest 
on the debt (see FAR 52.232-17, Interest).
    (e) If the Contractor fails to submit sales reports, falsifies sales 
report, or fails to pay the IFF In a timely manner, the Government may 
terminate or cancel this contract. Willful failure or refusal to furnish 
the required reports, falsification of sales reports, or failure to pay 
the IFF timely constitutes sufficient cause for terminating the 
Contractor

[[Page 251]]

for cause under the termination provisions of this contract.

                             (End of clause)

    * The Commissioner, Federal Supply Service or a designee determines 
and provides to contracting officers the percentage amount of the fee to 
insert in the above clause.



Sec. 552.242-70  Status Report of Orders and Shipments.

    As prescribed in 542.1107, insert the following clause:

            Status Report of Orders and Shipments (APR 1992)

    (a) The Contractor shall furnish to the Administrative Contracting 
Officer (ACO) a report covering orders received and shipments made 
during each calendar month of contract performance. The information 
required by the Government shall be reported on GSA Form 1678, Status 
Report of Orders and Shipments, in accordance with instructions on the 
form. The information required by the GSA Form 1678 may also be 
submitted in an automated printout form if authorized by the ACO. 
Alternatively, the required information may be reported by electronic 
data interchange using ANSI standards. For further information, contact 
GSA, Contract Administration Division [Insert appropriate telephone 
number of FQC] Reports shall be forwarded to the ACO no later than the 
seventh workday of the succeeding month.
    (b) An initial supply of GSA Form 1678 will be forwarded to the 
Contractor with the contract. Additional copies of the form, if needed, 
may be obtained from the ACO, or reproduced by the Contractor.

                             (End of clause)



Sec. 552.243-70  Pricing of Adjustments.

    As prescribed in 543.205(a)(1), insert the following clause:

                    Pricing of Adjustments (APR 1989)

    When costs are a factor in any determination of a contract price 
adjustment, such costs shall be in accordance with the contract cost 
principles and procedures in Part 31 of the Federal Acquisition 
Regulation (48 CFR Part 31) in effect on the date of this contract.

                             (End of clause)



Sec. 552.243-71  Equitable Adjustments.

    As prescribed in 543.205(a)(2), insert the following clause:

                    Equitable Adjustments (APR 1984)

    (a) The provisions of the ``Changes'' clause prescribed by FAR 
52.243-4 are supplemented as follows:
    (1) Upon written request, the Contractor shall submit a proposal, in 
accordance with the requirements and limitations set forth in the 
``Equitable Adjustments'' clause, for work involving contemplated 
changes covered by the request. The proposal shall be submitted within 
the time limit indicated in the request or any extension of such time 
limit as may be subsequently granted. The Contractor's written statement 
of the monetary extent of a claim for equitable adjustment shall be 
submitted in the following form:
    (i) Proposals totaling $5,000 or less shall be submitted in the form 
of a lump sum proposal with supporting information to clearly relate 
elements of cost with specific items of work involved to the 
satisfaction of the Contracting Officer, or his/her authorized 
representative.
    (ii) For proposals in excess of $5,000, the claim for equitable 
adjustment shall be submitted in the form of a lump sum proposal 
supported with an itemized breakdown of all increases and decreases in 
the contract in at least the following detail:

                              Direct Costs


Sec. Material quantities by trades and unit costs

    (Manufacturing burden associated with material fabrication performed 
will be considered to be part of the material costs of the fabricated 
item delivered to the job site)


Sec. Labor breakdown by trades and unit costs

    (Identified with specific item of material to be placed or operation 
to be performed)


Sec. Construction equipment exclusively necessary for the change

Sec. Costs of preparation and/or revision to shop drawings resulting 
          from the change

Sec. Workers' Compensation and Public Liability Insurance

Sec. Employment taxes under FICA and FUTA

Sec. Bond Costs--when size of change warrants revision

                     Overhead, Profit and Commission

    (2) The allowable overhead shall be determined in accordance with 
the contract cost principles and procedures in Part 31 of the Federal 
Acquisition Regulation (48 CFR part 31) in effect on the date of this 
contract. The percentages for profit and commission shall be negotiated 
and may vary according to the nature, extent and complexity of the work 
involved, but in no case shall exceed the following unless the 
Contractor demonstrates entitlement to a higher percentage:

[[Page 252]]



----------------------------------------------------------------------------------------------------------------
                                                                                     Profit         Commission
                                                           Overhead                (percent)        (percent)
----------------------------------------------------------------------------------------------------------------
To Contractor on work performed by other than  ...............................  ...............              10
 his own forces.
To first tier subcontractor on work performed  ...............................  ...............              10
 by his subcontractors.
To Contractor and/or the subcontractors for    To be Negotiated...............              10   ...............
 that portion of the work performed with
 their respective forces.
----------------------------------------------------------------------------------------------------------------

    Not more than four percentages will be allowed regardless of the 
number of tier subcontractors. The Contractor shall not be allowed a 
commission on the commission received by a first tier subcontractor. 
Equitable adjustments for deleted work shall include credits for 
overhead, profit and commission. On proposals covering both increases 
and decreases in the amount of the contract, the application of overhead 
and profit shall be on the net change in direct costs for the Contractor 
or subcontractor performing the work.
    (3) The Contractor shall submit with the proposal his request for 
time extension (if any), and shall include sufficient information and 
dates to demonstrate whether and to what extent the change will delay 
the contract in its entirety.
    (4) In considering a proposal, the Government shall make check 
estimates in detail, utilizing unit prices where specified or agreed 
upon, with a view to arriving at an equitable adjustment.
    (5) After receipt of a proposal the Contracting Officer shall act 
thereon, within 30 days; provided however, that when the necessity to 
proceed with a change does not allow time properly to check a proposal 
or in the event of failure to reach an agreement on a proposal, the 
Government may order the Contractor to proceed on the basis of price to 
be determined at the earliest practicable date. Such price shall not be 
more than the increase or less than the decrease proposed.
    (6) If a mutually acceptable agreement cannot be reached, the 
Contracting Officer may determine the price unilaterally.
    (b) The provisions of the ``Differing Site Conditions'' clause 
prescribed by FAR 52.236-2 are supplemented as follows: The Contractor 
shall submit all claims for equitable adjustment in accordance with, and 
subject to the requirements and limitations set out in paragraph (a) of 
this ``Equitable Adjustments'' clause.

                             (End of clause)



Sec. 552.243-72  Modifications (Multiple Award Schedule).

    As prescribed in 543.205(b), insert the following clause:

            Modifications (Multiple Award Schedule (JUL 2000)

    (a) General. The Contractor may request a contract modification by 
submitting a request to the Contracting Officer for approval, except as 
noted in paragraph (d) of this clause. At a minimum, every request shall 
describe the proposed change(s) and provide the rationale for the 
requested change(s).
    (b) Types of Modifications.
    (1) Additional items/additional SINs. When requesting additions, the 
following information must be submitted:
    (i) Information requested in paragraphs (1) and (2) of the 
Commercial Sales Practice Format to add SINs.
    (ii) Discount information for the new item(s) or new SIN(s). 
Specifically, submit the information requested in paragraphs 3 through 5 
of the Commercial Sales Practice Format. This information is the same as 
the initial award, a statement to that effect may be submitted instead.
    (iii) Information about the new item(s) or the item(s) under the new 
SIN(s) as described in 552.212-70, Preparation of Offer (Multiple Award 
Schedule) is required.
    (iv) Delivery time(s) for the new item(s) or the items under the new 
SIN(s) must be submitted in accordance with 552.211-78, Commercial 
Delivery Schedule (Multiple Award Schedule).
    (v) Production point(s) for the new item(s) or the item(s) under the 
new SIN(s) must be submitted if required by 52.215-6, Place of 
Performance.
    (vi) Hazardous material information (if applicable) must be 
submitted as required by 52.223-3 (ALT I), Hazardous Material 
Identification and Material Safety Data.
    (vii) Any information requested by 52.212-3(f), Offeror 
Representations and Certifications--Commercial Items, that may be 
necessary to assure compliance with FAR 52.225-1, Buy American Act--
Balance of Payments Programs--Supplies.
    (2) Deletions. The Contractor shall provide an explanation for the 
deletion. The Government reserves the right to reject any subsequent 
offer of the same item or a substantially equal item at a higher price 
during the same contract period, if the contracting officer finds the 
higher price to be unreasonable when compared with the deleted item.
    (3) Price Reduction. The Contractor shall indicate whether the price 
reduction falls

[[Page 253]]

under item (i), (ii), or (iii) of paragraph (c)(1) of the Price 
Reductions clause at 552.238-75. If the price reduction falls under item 
(i), the Contractor shall submit a copy of the dated commercial price 
list. If the price reduction falls under item (ii) or (iii), the 
Contractor shall submit a copy of the applicable price list(s), 
bulletins or letters or customer agreements which outline the effective 
date, duration, terms and conditions of the price reduction.
    (c) Effective Dates. The effective date of any modification is the 
date specified in the modification, except as otherwise provided in the 
Price Reductions clause at 552.238-75.
    (d) Electronic File Updates. The Contractor shall update electronic 
file submissions to reflect all modifications. For additional items or 
SINs, the Contractor shall obtain the contracting officer's approval 
before transmitting changes. Contract modifications will not be made 
effective until the Government receives the electronic file updates. The 
Contractor may transmit price reductions, item deletions, and 
corrections without prior approval. However, the Contractor shall notify 
the contracting officer as set forth in the Price Reductions clause at 
552.238-75.
    (e) Amendments to Paper Supply Schedule Price Lists.
    (1) The Contractor must provide supplements to its paper price 
lists, reflecting the most current changes. The Contractor may either:
    (i) Distribute a supplemental paper Federal Supply Schedule Price 
List within 15 workdays after the effective date of each modification.
    (ii) Distribute quarterly cumulative supplements. The period covered 
by a cumulative supplement is at the discretion of the Contractor, but 
may not exceed three calendar months from the effective date of the 
earliest modification. For example, if the first modification occurs in 
February, the quarterly supplement must cover February--April, and every 
3 month period after. The Contractor must distribute each quarterly 
cumulative supplement within 15 workdays from the last day of the 
calendar quarter.
    (2) At a minimum, the Contractor shall distribute each supplement to 
those ordering activities that previously received the basic document. 
In addition, the Contractor shall submit two copies of each supplement 
to the contracting officer, and one copy to the FSS Schedule Information 
Center.

                             (End of clause)

    Alternate I (Sep 1999). As prescribed in 543.205(b), substitute the 
following paragraph (d) for paragraph (d) of the basic clause:

    (d) Electronic File Updates. The Contractor shall update electronic 
file submissions to reflect all modifications. For additional items or 
SINs, the Contractor shall obtain the contracting officer's approval 
before transmitting changes. Contract modifications will not be made 
effective until the Government receives the electronic file updates. The 
Contractor may transmit price reductions and corrections without prior 
approval. However, the Contractor shall notify the contracting officer 
as set forth in the Price Reductions clause at 552.238-75.

[64 FR 37229, July 9, 1999, as amended at 65 FR 41379, July 5, 2000]



Sec. 552.246-17  Warranty of Supplies of a Noncomplex Nature

    As prescribed in 546.710(a), insert the following clause:

 Warranty of Supplies of a Noncomplex Nature (DEC 1990) (Deviation FAR 
                               52.246-17)

    (a) Definitions. ``Acceptance,'' as used in this clause, means the 
act of an authorized representative of the Government by which the 
Government assumes for itself, or as an agent of another, ownership of 
existing supplies, or approves specific services as partial or complete 
performance of the contract.
    ``Correction,'' as used in this clause, means the elimination of a 
defect.
    ``Supplies,'' as used in this clause, means the end item furnished 
by the Contractor and related services required under the contract. The 
word does not include ``data.''
    (b) Contractor's obligations.
    (1) Notwithstanding inspection and acceptance by the Government of 
supplies furnished under this contract, or any condition of this 
contract concerning the conclusiveness thereof, the Contractor warrants 
that for ____*____
    (i) All supplies furnished under this contract will be free from 
defects in material or workmanship and will conform with the 
requirements of this contract; and
    (ii) The preservation, packaging, packing, and marking, and the 
preparation for, and method of, shipment of such applies will conform 
with the requirements of this contract.
    (2) When return, correction, or replacement is required, the 
Contractor shall be responsible for all costs attendant to the return, 
correction or replacement of the nonconforming supplies. Any removal in 
connection with the above shall be done by the Contractor at its 
expense. However, the Contractor's liability for the transportation 
charges shall not exceed an amount equal to the cost of transportation 
by the usual commercial method of shipment between the place of delivery 
specified in the contract and the Contractor's plant, and return.

[[Page 254]]

    (3) Any supplies or parts thereof, corrected or furnished in 
replacement under this clause, shall also be subject to the terms of 
this clause to the same extent as supplies initially delivered. The 
warranty, with respect to supplies or parts thereof, shall be equal in 
duration to that in paragraph (b)(1) of this clause and shall run from 
the date of delivery of the corrected or replaced supplies.
    (4) All implied warranties of merchantability and ``fitness for a 
particular purpose'' are excluded from any obligation contained in this 
contract.
    (c) Remedies available to the Government.
    (1) The Contracting Officer shall give written notice to the 
Contractor of any breach of warranties in paragraph (b)(1) of this 
clause with ____*____. This notice shall contain information concerning 
the deficiencies found, the location of the nonconforming supplies, and 
the quantity involved.
    (2) Within a reasonable time after the notice, the Contracting 
Officer may either--
    (i) Require, by written notice, the prompt correction or replacement 
of any supplies or parts thereof (including preservation, packaging, 
packing, and marking) that do not conform with the requirements of this 
contract within the meaning of paragraph (b)(1) of this clause; or
    (ii) Retain such supplies and reduce the contract price by an amount 
equitable under the circumstances. When the nature of the defect in the 
nonconforming item is such that the defect affects an entire batch or 
lot of material, then the equitable price adjustment shall apply to the 
entire batch or lot of material from which the nonconforming item was 
taken.
    (3)(i) If the contract provides for inspection of supplies by 
sampling procedures, conformance of supplies or components subject to 
warranty action shall be determined by the applicable sampling 
procedures in the contract. The Contracting Officer--
    (A) May, for sampling purposes, group any supplies delivered under 
this contract;
    (B) Shall require the size of the sample to be that required by 
sampling procedures specified in the contract for the quantity of 
supplies on which warranty action is proposed;
    (C) May project warranty sampling results over supplies in the same 
shipment or other supplies contained in other shipments even though all 
of such supplies are not present at the point of reinspection; provided, 
that the supplies remaining are reasonably representative of the 
quantity on which warranty action is proposed; and
    (D) Need not use the same lot size as on original inspection or 
reconstitute the original inspection lots.
    (ii) Within a reasonable time after notice of any breach of the 
warranties specified in paragraph (b)(1) of this clause, the Contracting 
Officer may exercise one or more of the following options:
    (A) Require an equitable adjustment in the contract price for any 
group of supplies.
    (B) Screen the supplies grouped for warranty action under this 
clause at the Contractor's expense and return all nonconforming supplies 
to the Contractor for correction or replacement.
    (C) Require the Contractor to screen the supplies at locations 
designated by the Government within the continental United States and to 
correct or replace all nonconforming supplies.
    (D) Return the supplies grouped for warranty action under this 
clause to the Contractor (irrespective of the f.o.b. point or the point 
of acceptance) for screening and correction or replacement. All costs 
incurred by the Government in returning the nonconforming supplies, 
including costs to the freight carrier resulting from the Contractor's 
refusal to accept their return, shall be for the Contractor's account.
    (4)(i) The Contracting Officer may, by contract or otherwise, 
correct or replace the nonconforming supplies with similar supplies from 
another source and charge to the Contractor the cost occasioned to the 
Government thereby if the Contractor--
    (A) Fails to make redelivery of the corrected or replaced supplies 
within the time established for their return; or
    (B) Fails either to accept return of the nonconforming supplies or 
fails to make progress after their return to correct or replace them so 
as to endanger performance of the delivery schedule, and in either of 
these circumstances does not cure such failure within a period of 10 
days (or such longer period as the Contracting Officer may authorize in 
writing) after receipt of notice from the Contracting Officer specifying 
such failure.
    (ii) Instead of correction or replacement by the Government, the 
Contracting Officer may require an equitable adjustment of the contract 
price for all nonconforming supplies, including batch or lot materials 
which either have been consumed or other disposition has been made. In 
addition, if the Contractor fails to furnish timely disposition 
instructions, the Contracting Officer may return the supplies for 
screening and correction or replacement under subparagraph (c)(3)(ii)(D) 
above; store the nonconforming supplies for the Contractor's account; 
sell the nonconforming supplies to the highest bidder on the open market 
and apply the proceeds against the accumulated storage and other costs, 
including the cost of the sale; or otherwise dispose of the 
nonconforming supplies for the Contractor's account in a reasonable 
manner. The Government is entitled to reimbursement from the Contractor, 
or from the proceeds of such disposal, for the

[[Page 255]]

reasonable expenses of the care and disposition of the nonconforming 
supplies, as well as for excess costs incurred or to be incurred.
    (5) The rights and remedies of the Government provided in this 
clause are in addition to and do not limit any rights afforded to the 
Government by any other clause of this contract.
    (6) Unless otherwise provided, this warranty is applicable both 
within and outside the continental limits of the United States.
    (7) In addition to other marking requirements of this contract, the 
Contractor shall stamp or mark the supplies delivered or otherwise 
furnish notice with the supplies of the existence of the warranty. The 
marking should briefly include (i) a statement that the warranty exists, 
(ii) the substance of the warranty, (iii) its duration, and (iv) whom to 
notify if the supplies are found to be defective.

                             (End of clause)

    * State the specific period of time after delivery or the specified 
event whose occurrence will terminate the warranty period; e.g., the 
number of miles or hours of use, or combination of any applicable event 
or periods of time.
    ** Insert specific period of time; e.g., ``45 days from the last 
delivery under this contract,'' or ``45 days after discovery of the 
defect.'' The number of days specified shall be no less than 30.
    Alternate I (DEC 1990). As prescribed in 546.710(a)(1), substitute 
the following for paragraph (b)(1) of the basic clause and delete 
paragraph (b)(4) of the basic clause.

    (1) Notwithstanding inspection and acceptance by the Government of 
supplies furnished under this contract, or any condition of this 
contract concerning the conclusiveness thereof, the Contractor warrants 
that for ____*____ all supplies furnished--
    (i) Are of a quality to pass without objection in the trade under 
the contract description;
    (ii) Are fit for the ordinary purposes for which the supplies are 
used;
    (iii) Are within the variations permitted by the contract, and are 
of an even kind, quality, and quantity within each unit and among all 
units;
    (iv) Are adequately contained, packaged, and marked as the contract 
may require; and
    (v) Conform to the promises or affirmations of fact made on the 
container.

    Alternate II (DEC 1990). As prescribed in 546.710(a)(2), substitute 
the following paragraph for paragraph (b)(1) of the basic clause:

    (1) Notwithstanding inspection and acceptance by the Government of 
supplies furnished under this contract, or any condition of this 
contract concerning the conclusiveness thereof, the Contractor warrants 
that for ____*____ all supplies furnished--
    (i) Conform to the specifications except that in the case of solvent 
systems, the viscosity may exceed the specified maximum by 10 Kreb 
Units, unless otherwise specified elsewhere in this contract; and
    (ii) Are suitable for their intended purpose as stated in this 
contact.

    Alternate III (DEC 1990). As prescribed in 546.710(a)(3), substitute 
the following for paragraph (b)(1) of the basic clause, redesignate 
paragraph (c) of the basic clause as paragraph (d), and add the 
following as paragraph (c) in the basic clause:

    (1) Notwithstanding inspection and acceptance by the Government of 
supplies furnished under this contract, or any condition of this 
contract concerning the conclusiveness thereof, the Contractor warrants 
that for ____*____, beginning with the first day of the first full month 
following the month of manufacture marked on the container, all supplies 
furnished retain their original characteristics to the extent that the 
supplies remain suitable for the intended use as stated in this contract 
(i) under actual application conditions or (ii) when tested in 
accordance with requirements stated elsewhere in this contract.
    (c) Government surveillance and testing.
    (1) During this period, surveillance will be maintained on supplies 
warehoused in Government facilities; and the supplies will be tested 
periodically to determine their suitability for intended use. Sampling 
for surveillance testing will be in accordance with Military Standard 
No. 105, and such testing will be made after NORMAL MIXING, STIRRING, OR 
SHAKING, in accordance with directions either furnished with the 
supplies or as shown in the applicable specifications.
    (2) Surveillance testing will be based on storage stability 
requirements set forth in the contract specification, or purchase 
description on the basis of salient characteristics (e.g., viscosity or 
sag flow, curing time, strip adhesion or tensile shear, etc.) 
established by GSA as appropriate to determine suitability for intended 
use. In the case of brand name items not covered by detailed purchase 
descriptions, surveillance testing may be based on salient 
characteristics included in the manufacturer's data sheets. If storage 
stability requirements showing allowable variations are not included in 
applicable specifications or elsewhere in the contract, material will be 
considered suitable for intended use if the salient characteristics vary 
not more than 20 percent from the

[[Page 256]]

originally specified values (i.e., those applicable to acceptance 
testing of the supplies) for noncritical end-use items, and not more 
then 10 percent for critical end-use items.



Sec. 552.246-70  Source Inspection by Quality Approved Manufacturer.

    As prescribed in 546.302-70, insert the following clause:

      Source Inspection by Quality Approved Manufacturer (SEP 1999)

    (a) Inspection system and inspection facilities.
    (1) The inspection system maintained by the Contractor under the 
Inspection of Supplies--Fixed Price clause (FAR 52.246-2) of this 
contract shall be maintained throughout the contract period and shall 
comply with all requirements of editions in effect on the date of the 
solicitation of either Federal Standard 368 or the International 
Organization for Standardization (ISO) Standard 9001 (ANSI/ASQC Q 91) 
(Quality Systems--Model for Quality Assurance in Design/Development, 
Production, Installation and Servicing), or ISO Standard 9002 (ANSI/ASQC 
Q 92) (Quality Systems--Model for Quality Assurance in Production and 
Installation). The ISO 9000 family of standards is a set of worldwide 
standards used to document, implement and demonstrate quality assurance 
systems. When using the ISO option the Contractor's quality system must 
be registered by a third party registrar accredited by either the 
Registrar Accreditation Board (RAB) or an organization recognized as 
equivalent. A written description of the inspection system shall be made 
available to the Government before contract award. The Contractor shall 
immediately notify the Contracting Officer and the designated GSA 
quality assurance office of any changes made in the inspection system 
during the contract period. As used herein, the term ``inspection 
system'' means the Contractor's own facility or any other facility 
acceptable to the Government that will be used to perform inspections or 
tests of materials and components before incorporation into end articles 
and for inspection of such end articles before shipment. When the 
manufacturing plant is located outside of the United States, the 
Contractor shall arrange delivery of the items from a plant or warehouse 
located in the United States (including Puerto Rico and the Virgin 
Islands) equipped to perform all inspections and tests required by the 
contract or specifications to evidence conformance therewith, or shall 
arrange with a testing laboratory or other facility in the United 
States, acceptable to the Government, to perform the required 
inspections and tests.
    (2) In addition to the requirements in Federal Standard 368, ISO 
9001 or ISO 9002 records shall include the date when inspection and 
testing were performed. These records shall be available for (i) 3 years 
after final payment; or (ii) 4 years from the end of the Contractor's 
fiscal year in which the record was created, whichever period expires 
first.
    (3) Offerors are required to specify, in the space provided 
elsewhere in this solicitation, the name and address of each 
manufacturing plant or other facility where supplies will be available 
for inspection, indicating the item number(s) to which each applies.
    (4) Within 10 calendar days after receipt of the written notice of 
award, the Contractor shall provide the Administrative Contracting 
Officer with the name of the individual and an alternate that will be 
responsible for inspecting each shipment under this contract.
    (b) Inspection and receiving reports.
    (1) For each shipment released, one of the officials named by the 
Contractor under paragraph (a)(4) above shall sign a Quality Approved 
Manufacturer Certificate certifying that supplies have been inspected 
and found to comply with contract requirements. The certification shall 
read as follows:
    ``I certify that all items in this shipment have been listed herein, 
and have been inspected and found to comply with all requirements of the 
contract.''

                    Signature of Certifying Official

    (2) For shipments made to military facilities, the Contractor shall 
prepare and distribute the DD Form 250, Material Inspection and 
Receiving Report, or computer formatted equivalent of the form not later 
than the close of business the workday following shipment. The 
certification above shall be placed in block 16 on this form. The 
Contractor will be provided a supply of the DD Form 250 with complete 
instructions for preparation and distribution.
    (3) For shipments made to civilian facilities only, the Contractor 
shall prepare and distribute not later than the close of business the 
workday following shipment a certification of inspection and conformance 
for the identified items, in accordance with instructions furnished at 
the time of award. The Contractor may furnish the requisite information 
on the DD Form 250 or computer formatted equivalent, company letterhead, 
or invoice document.
    (c) Inspection by Government personnel.
    (1) Although the Government will normally rely upon the Contractor's 
certification as to the quality of supplies shipped, it reserves the 
right under the Inspection of Supplies--Fixed Price clause to inspect 
and test all supplies called for by this contract, before acceptance, at 
all times and places, including the point of manufacture. When the 
Government notifies the Contractor of its intent to inspect supplies 
before shipment, the Contractor shall notify or arrange for 
subcontractors to notify the designated

[[Page 257]]

GSA quality assurance office 7 workdays before the date when supplies 
will be ready for inspection. Shipment shall not be made until 
inspection by the Government is completed and shipment is authorized by 
the Government.
    (2) Government inspection responsibility will be assigned the GSA 
quality assurance office which has jurisdiction over the State in which 
the Contractor's or subcontractor's plant or other designated point for 
inspection is located.
    (3) During the contract period, a Government representative may 
periodically select samples of supplies produced under this contract for 
verification inspection and testing. Samples sent to a Government 
testing facility will be disposed of as follows: Samples from an 
accepted lot, not damaged in the testing process, will be returned 
promptly to the Contractor after completion of tests. Samples damages in 
the testing process will be disposed of as requested by the Contractor. 
Samples from a rejected lot will be returned to the Contractor or 
disposed of in a time and manner agreeable to both the Contractor and 
the Government.
    (d) Quality deficiencies.
    (1) Notwithstanding any other clause of this contract concerning the 
conclusiveness of acceptance by the Government, any supplies or 
production lots shipped under this contract found to be defective in 
material or workmanship, or otherwise not in conformity with the 
requirements of this contract within a period of ____*____ months after 
acceptance shall, at the Government's option, be replaced, repaired or 
otherwise corrected by the Contractor at no cost to the Government 
within 30 calendar days (or such longer period as the Government may 
authorize in writing) after receipt of notice to replace or correct. The 
Contractor shall remove, at its expense, supplies rejected or required 
to be replaced, repaired or corrected. When the nature of the defect 
affects an entire batch or lot of supplies, and the Contracting Officer 
determines that correction can best be accomplished by retaining the 
nonconforming supplies and reducing the contract price by an amount 
equitable under the circumstances, then the equitable price adjustment 
shall apply to the entire batch or lot of supplies from which the 
nonconforming item was taken.
    (2) If supplies in process, shipped, or awaiting shipment to fill 
Government orders are found not to comply with contract requirements, or 
if deficiencies in either plant quality or process controls are found, 
the Contractor may be issued a Quality Deficiency Notice (QDN). Upon 
receipt of a QDN, the Contractor shall take immediate corrective action 
and shall suspend shipment of the supplies covered by the QDN until such 
time as corrective action has been completed. The Contractor shall 
notify the GSA quality assurance office, within 5 workdays, of 
corrective action taken or to be taken to permit on site verification by 
a Government representative. Shipments of nonconforming supplies will be 
returned at the Contractor's expense and may constitute cause for 
termination. Delays due to the insurance of a QDN do not constitute 
excusable delay under the Default clause. Failure to complete corrective 
action in a timely manner may result in termination of this contract.
    (3) This contract may be terminated for default if subsequent 
Government inspection discloses that plant quality or process controls 
are not being maintained, supplies which do not meet the requirements of 
the specification are being shipped, or there is failure to comply with 
any other requirement of this clause.
    (e) Additional cost for inspection and testing. The Contractor will 
be charged for any additional cost of inspection/testing or 
reinspecting/retesting supplies for the reasons stated in paragraph (e) 
of FAR 52.246-2, Inspection of Supplies--Fixed Price. When inspection or 
testing is performed by or under the direction of GSA, charges will be 
at the rate of $____*____ per man-hour or fraction thereof if the 
inspection is at a GSA distribution center; $____*____ per man-hour or 
fraction thereof, plus travel costs incurred, if the inspection is at 
any other location; and $____*____ per man-hour or fraction thereof for 
laboratory testing, except that when a testing facility other than a GSA 
laboratory performs all or part of the required tests, the Contractor 
shall be assessed the actual cost incurred by the Government as a result 
of testing at such facility. When inspection is performed by or under 
the direction of any agency other than GSA, the charges indicated above 
may be used, or the agency may assess the actual cost of performing the 
inspection and testing.
    (f) Responsibility for rejected supplies. When the Contractor fails 
to remove or provide instructions for the removal of rejected supplies 
under paragraph (d) above, pursuant to the Contracting Officer's 
instructions, the Contractor shall be liable for all costs incurred by 
the Government in taking such measures as are expedient to avoid 
unnecessary loss to the Contractor. In addition to the remedies provided 
in FAR 52.246-2, supplies may be--
    (1) Stored for the Contractor's account;
    (2) Reshipped to the Contractor at its expense (any additional 
expense incurred by the Government or the freight carrier caused by the 
refusal of the Contractor to accept their return also shall be for the 
Contractor's account); or
    (3) Sold to the highest bidder on the open market and the proceeds 
applied against the accumulated storage and other costs, including the 
cost of the sale.

[[Page 258]]

    (g) Subcontracting requirements. The Contractor shall insert in any 
subcontracts the inspection or testing provisions set forth in 
paragraphs (a) through (d) of this clause and the Inspection of 
Supplies--Fixed Price clause of this contract. The Contractor shall be 
responsible for compliance by any subcontractor with the provisions set 
forth in paragraphs (a) through (d) of this clause and the Inspection of 
Supplies--Fixed Price clause.

                             (End of clause)

    * Normally insert 12 months as the period during which defective or 
otherwise nonconforming supplies must be replaced. However, when the 
supplies being bought have a shelf life of less than 1 year, you should 
use the shelf-life period, or in the instance where you reasonably 
expect a longer period to be available, you should use the longer 
period.
    ** The rates to be inserted are established by the Commissioner of 
the Federal Supply Service or a designee.



Sec. 552.246-71  Source Inspection by Government.

    As prescribed in 546.302-71, insert the following clause:

                Souce Inspection by Government (SEP 1999)

    (a) Inspection by Government personnel.
    (1) Supplies to be furnished under this contract will be inspected 
at source by the Government before shipment from the manufacturing plant 
or other facility designated by the Contractor, unless the Contractor is 
otherwise notified in writing by the Contracting Officer or a designated 
representative. Notwithstanding the foregoing, the Government may 
perform any or all tests contained in the contract specifications at a 
Government facility without prior written notice by the Contracting 
Officer before release of the supplies for shipment. Samples sent to a 
Government resting facility will be disposed of as follows: Samples from 
an accepted lot, not damaged in the testing process, will be returned 
promptly to the Contractor after completion of tests. Samples damaged in 
the testing process will be disposed of as requested by the Contractor. 
Samples from a rejected lot will be returned to the Contractor or 
disposed of in a time and manner agreeable to both the Contractor and 
the Government.
    (2) Government inspection responsibility will be assigned to the GSA 
quality assurance office which has jurisdiction over the State in which 
the Contractor's subcontractor's plant or other designated point for 
inspection is located. The Contractor shall notify or arrange for 
subcontractors to notify the designated GSA quality assurance office 7 
workdays before the date when supplies will be ready for inspection. 
Shipment shall not be made until after inspection by the Government is 
completed and shipment is authorized by Government.
    (b) Inspection and receiving reports. For each shipment, the 
Contractor shall be responsible for preparation and distribution of 
inspection documents as follows: (1) DD Form 250, Material Inspection 
and Receiving Report, or computer formatted equivalent for deliveries to 
military agencies; or (2) GSA Form 308, Notice of Inspection for 
deliveries to GSA or other civilian agencies. When required, the 
Contractor will be furnished a supply of GSA Form 308 and/or DD Form 
250, and complete instructions for their reparation and distribution.
    (c) Inspection facilities.
    (1) The inspection system required to be maintained by the 
Contractor in accordance with FAR 52.246-2, Inspection of Supplies--
Fixed Price, may be the Contractor's own facilities or any other 
facilities acceptable to the Government. The facilities shall be 
utilized to perform all inspections and tests of materials and 
components before incorporation into end articles, and for the 
inspection of such end articles before shipment. The Government reserves 
the right to evaluate the acceptability and effectiveness of the 
Contractor's inspection system before award and periodically during the 
contract period.
    (2) Offerors are required to specify, in the spaces provided 
elsewhere in the solicitation, the name and address of each 
manufacturing plant or other facility where supplies will be available 
for inspection, indicating the item number(s) to which each applies.
    (3) The Contractor shall deliver the items specified in this 
contract from a plant or warehouse located within the United States 
(including Puerto Rico and the Virgin Islands) that is equipped to 
perform all inspections and tests required by this contract or 
specifications to evidence conformance therewith, or shall arrange with 
a testing laboratory or other facility in the United States, acceptable 
to the Government, to perform the required inspections and tests.
    (d) Availability of records.
    (1) In addition to any other requirement of this contract, the 
Contractor shall maintain records showing the following information for 
each order received under the contract: (i) order number; (ii) date 
order received by the Contractor; (iii) quantity ordered; (iv) date 
scheduled into production; (v) batch or lot number, if applicable; (vi) 
date inspected and/or tested; (vii) date available for shipment; (viii) 
date shipped or date service completed; and (ix) National Stock Number 
(NSN), or if none is provided in the contract, the applicable item 
number or other contractual identification.

[[Page 259]]

    (2) These records should be maintained at the point of source 
inspection and shall be available to the Contracting Officer, or an 
authorized representative, for (i) 3 years after final payment; or (ii) 
4 years from the end of the Contractor's fiscal year in which the record 
was created, whichever period expires first.
    (e) Additional cost for inspection and testing. The Contractor will 
be charged for any additional cost for inspecting/testing or 
reinspection/retesting supplies for the reasons stated in paragraph (e) 
of FAR 52.246-2, Inspection of Supplies--Fixed Price. When inspection or 
testing is performed by or under the direction of GSA, charges will be 
at the rate of $____*____ per man-hour or fraction thereof if the 
inspection is at a GSA distribution center; $____*____ per man-hour or 
fraction thereof, plus travel costs incurred, if the inspection is at 
any other location; and $____*____ per man-hour or fraction thereof for 
laboratory testing, except that when a testing facility other than a GSA 
laboratory performs all or part of the required tests, the Contractor 
shall be assessed the actual cost incurred by the Government as a result 
of testing at such facility. When inspection is performed by or under 
the direction of any agency other than GSA, the charges indicated above 
may be used, or the agency may assess the actual cost of performing the 
inspection and testing.
    (f) Responsibility for rejected supplies. When the Contractor fails 
to remove or provide instructions for the removal of rejected supplies 
under FAR 52.246-2(h) pursuant to the Contracting Officer's 
instructions, the Contractor shall be liable for all costs incurred by 
the Government in taking such measures as are expedient to avoid 
unnecessary loss to the Contractor. In addition to the remedies provided 
in FAR 52.246-2, supplies may be--
    (1) Stored for the Contractor's account;
    (2) Reshipped to the Contractor at its expense (any additional 
expense incurred by the Government or the freight carrier caused by the 
refusal of the Contractor to accept their return also shall be for the 
Contractor's account); or
    (3) Sold to the highest bidder on the open market and the proceeds 
applied against the accumulated storage and other costs, including the 
cost of the sale.

                             (End of clause)

    * The rates to be inserted are established by the Commissioner of 
the Federal Supply Service or a designee.



Sec. 552.246-72  Final Inspection and Tests.

    As prescribed in 546.312, insert the following clause:

                  Final Inspection and Tests (SEP 1999)

    The Contractor shall give written notice to the Contracting Officer 
at least 10 calendar days before the date the work will be completed and 
ready for final inspection and tests. Final inspection and tests will 
begin within 10 calendar days after the date specified in the 
Contractor's notice unless the Contracting Officer determines that the 
work is not ready for final inspection and so informs the Contractor.

                             (End of clause)



Sec. 552.246-73  Warranty--Multiple Award Schedule.

              Warranty--Multiple Award Schedule (MAR 2000)

    (a) Applicable to domestic locations. Unless specified otherwise in 
this contract, the Contractor's standard commercial warranty as stated 
in the Contractor's commercial price list applies to this contract.
    (b) Applicable to overseas destinations. Unless specified otherwise 
in this contract, the Contractor's standard commercial warranty as 
stated in the commercial price list applies to this contract, except as 
follows:
    (1) The Contractor must provide, at a minimum, a warranty on all 
non-consumable parts for a period of 90 days from the date that the 
Government accepts the product.
    (2) The Contractor must supply parts and labor required under the 
warranty provisions free of charge.
    (3) The Contractor must bear the transportation costs of returning 
the products to and from the repair facility, or the costs involved with 
Contractor personnel traveling to The Government facility for the 
purpose of repairing the product onsite, during the 90-day warranty 
period.

                             (End of clause)

[65 FR 11248, Mar. 2, 2000]



Sec. 552.246-74  [Reserved]



Sec. 552.246-75  Guarantees.

    As prescribed in 546.710(c), insert the following clause.

                          Guarantees (MAY 1989)

    (a) Unless otherwise provided in the specifications, the Contractor 
guarantees all work to be in accordance with contract requirements and 
free from defective or inferior materials, equipment, and workmanship 
for 1 year after the date of final acceptance or the date the equipment 
or work was placed in use by the Government, whichever occurs first.

[[Page 260]]

    (b)(1) If, within any guarantee period, the Contracting Officer 
finds that guaranteed work requires repair or change because of 
defective or inferior materials, equipment, or workmanship or is not in 
accordance with contract requirements, the Contracting Officer shall 
notify the Contractor in writing. The Contractor shall promptly, and 
without additional expense to the Government, correct:
    (i) All guaranteed work;
    (ii) All damage to equipment, the site, the building or its contents 
resulting from the unsatisfactory guaranteed work; and
    (iii) Any work, materials, and equipment that are disturbed in 
fulfilling the guarantee, including any disturbed work, materials, and 
equipment that may have been guaranteed under another contract.
    (2) If the Contractor fails to proceed promptly in accordance with 
the guarantee, the Government may have such work performed at the 
expense of the Contractor.
    (c) Any special guarantees that may be required under the contract 
will be subject to paragraphs (a) and (b), insofar as they do not 
conflict with special guarantees.
    (d) The Contractor shall furnish to the Government: (1) Each 
transferable guarantee or warranty of equipment, materials, or 
installation furnished by any manufacturer, supplier, or installer in 
the ordinary course of business; (2) All information required to make 
such guarantee or warranty legally binding and effective; and (3) The 
information and the guarantee or warranty in sufficient time to permit 
the Government to meet any time limit specified in the guarantee or 
warranty or, if no time limit is specified, prior to completion and 
acceptance of all work under this contract.

                             (End of clause)

[64 FR 37229, July 9, 1999, as amended at 65 FR 11249, Mar. 2, 2000]



Sec. 552.246-76  Warranty of Pesticides.

    As prescribed in 546.710(d), insert the following clause:

                    Warranty of Pesticides (MAY 1989)

    (a) Notwithstanding acceptance of pesticides by the Government, the 
Contractor warrants that for 1 year after the date of shipment, all 
pesticides furnished under this contract shall meet the requirements of 
Pub. L. 92-516, as amended, and shall be registered with the 
Environmental Protection Agency (EPA).
    (b) If EPA takes action to stop sale, stop use, remove, seize, or 
cancel registration of a pesticide within 1 year after date of shipment, 
the Contractor shall immediately notify the Contracting Officer. The 
notification will include: (1) contract number; (2) identification of 
the pesticide; (3) reason for the EPA action against the pesticide; and 
(4) list of Government agencies and addresses to which it was delivered.

                             (End of clause)

[64 FR 37229, July 9, 1999, as amended at 65 FR 11249, Mar. 2, 2000]



Sec. 552.247-70  Placarding Railcar Shipments.

    As prescribed in 547.305(a), insert the following clause:

                 Placarding Railcar Shipments (MAY 1989)

    When a railcar is loaded in such a manner that it can be or should 
be unloaded from only one side, the Contractor shall place on the 
appropriate railcar door a placard reading ``UNLOAD FROM THIS SIDE'' and 
on the opposite door a placard reading ``UNLOAD FROM OTHER SIDE.''

                             (End of clause)



Sec. 552.247-71  Diversion of Shipment Under F.O.B. Destination 
          Contracts.

    As prescribed in 547.305(b), insert the following clause:

   Diversion of Shipment Under F.O.B. Destination Contracts (MAR 2000)

    (a) Notwithstanding paragraph (c) of the clause in this contract 
titled 52.212-4, Contract Terms and Conditions--Commercial Items, the 
Government has the unilateral right to make changes at any time within 
the general scope of this contract in either the:
    (1) Method of shipment or packing.
    (2) Place of delivery.
    (b) If any such change causes an increase or decrease in the cost of 
this contract, the Contracting Officer shall make an equitable 
adjustment in the contract price, the delivery schedule, or both. The 
Contractor must assert its right to an adjustment under this clause 
within 30 days from the date of receipt of a delivery order.
    (c) The Government shall make no adjustment when supplies are 
identically priced for delivery regionally or nationally and the place 
of delivery is changed within the area to which the identical price 
applies. In all other cases, adjustments for changes in transportation 
costs under this clause shall be determined as follows:
    (1) If the contractor ships by contract or common carrier, price 
adjustments shall be determined by comparing the cost of shipments to 
the new destination(s), as evidenced by copy of paid freight bills 
supplied

[[Page 261]]

by the Contractor with the invoice, to one of the following:
    (i) The cost of shipments to the standard contract destination, as 
evidenced by copy of appropriate paid freight bills supplied by the 
Contractor.
    (ii) If no shipments have been made to the standard contract 
destination, the cost as evidenced by the applicable rates of a common 
or contract carrier. If carrier rates are not publicly filed with a 
regulatory body (e.g., interstate shipments moving by rail piggyback 
service), the Contractor shall provide a copy of the contract, letter 
agreement, or other written communication from the carrier(s) quoting 
the rates/charges that would have applied for shipments to the standard 
contract destination.
    (2) If (i) shipments to the new destination are made by the 
Contractor's owned or leased trucks or (ii) shipments to the original 
destination were or would have been made by the Contractor's owned or 
leased trucks, the Government shall determine the adjustment by 
substituting a rate equal to 70 percent of the lowest applicable rate 
published in common carrier rates as of the date of shipment for the 
Contractor's actual rate or contemplated transportation costs.
    (d) If the copies of paid freight bills for a diverted shipment do 
not show, or make readily available, each of the following items,the 
Contractor shall supply a written statement showing the item(s):
    (1) Full name of each carrier in the routing.
    (2) Number of containers.
    (3) Gross shipping weight.
    (4) Actual date of shipping.
    (5) Freight description for the supplies as indicated in the 
``National Motor Freight Classification'' or the ``Uniform Freight 
Classification'' (Rail).

                             (End of clause)

[64 FR 37229, July 9, 1999, as amended at 65 FR 11249, Mar. 2, 2000]



Sec. 552.249-70  Termination for Convenience of the Government (Fixed 
          Price) (Short Form).

    As prescribed in 549.502(a) insert the following clause:

Termination for Convenience of the Government (Fixed-Price) (Short Form) 
            (MAY 1988) (Deviation FAR 52.249-1 and 52.249-2)

    (a) If the Government terminates this contract for convenience, the 
rights of the Government and the Contractor shall be determined under 
paragraph (b) unless there is a termination liability schedule, in which 
case the rights of the parties shall be determined under paragraph (c).
    (b) The clause at [Contracting Officer inserts 52.249-1 or 52.249-2, 
as applicable] of the FAR shall apply to the supply portion of the 
contract and the clauses at 52.249-4 of the FAR shall apply to the 
service portion of the contract.
    (c) If the Contractor specifies a schedule of termination liability 
charges that would be incurred by the Government if the Government 
terminates this lease contract without taking title to the equipment, 
the payment of such charges shall be the only responsibility of the 
Government to compensate the Contractor for such termination; except 
that, there shall be no termination liability for equipment installed 
after termination of this contract.

                             (End of clause)



Sec. 552.249-71  Submission of Termination Liability Schedule.

    As prescribed in 549.502(b), insert the following clause:

         Submission of Termination Liability Schedule (May 1989)

    (a) An offeror may submit, as part of its proposal, a termination 
liability schedule to be applied if any resultant contract is terminated 
by the Government for reasons other than default. The offeror shall 
provide and explain the amount and method of computation of the 
termination liability charge(s).
    (b) If submitted, the termination liability schedule will be 
incorporated into Part I, Section B of the contract document. If a 
termination liability schedule is not submitted and the Government 
terminates any resultant contract for its convenience, the rights of the 
parties shall be determined under paragraph (b) of the GSAR Termination 
for Convenience of the Government clause at 552.249-70.
    (c) Any termination liability charges existing at the end of the 
evaluated contract period will be considered in the evaluation of 
offers.

                             (End of clause)



Sec. 552.252-5  Authorized Deviations in Provisions.

    As prescribed in 552.107-70(a), insert the following provision:

 Authorized Deviations in Provisions (Deviation FAR 52.252-5) (SEP 1999)

    (a) Deviations to FAR provisions.
    (1) This solicitation indicates any authorized deviation to a 
Federal Acquisition Regulation (48 CFR chapter 1) provision by the 
addition of ``(DEVIATION)'' after the date of

[[Page 262]]

the provision, if the provision is not published in the General Services 
Administration Acquisition Regulation (48 CFR chapter 5).
    (2) This solicitation indicates any authorized deviation to a 
Federal Acquisition Regulation (FAR) provision that is published in the 
General Services Administration Acquisition Regulation by the addition 
of ``(DEVIATION (FAR provision no.))'' after the date of the provision.
    (b) Deviations to GSAR provisions. This solicitation indicates any 
authorized deviation to a General Services Administration Acquisition 
Regulation provision by the addition of ``(DEVIATION)'' after the date 
of the provision.
    (c) ``Substantially the same as'' provisions. Changes in wording of 
provisions prescribed for use on a ``substantially the same as'' basis 
are not considered deviations.

                           (End of provision)



Sec. 552.252-6  Authorized Deviations in Clauses.

    As prescribed in 552.107-70(b), insert the following clause:

  Authorized Deviations in Clauses (Deviation FAR 52.252-6) (SEP 1999)

    (a) Deviations to FAR clauses.
    (1) This solicitation or contract indicates any authorized deviation 
to a Federal Acquisition Regulation (48 CFR chapter 1) clause by the 
addition of ``(DEVIATION)'' after the date of the clause, if the clause 
is not published in the General Services Administration Acquisition 
Regulation (48 CFR chapter 5).
    (2) This solicitation indicates any authorized deviation to a 
Federal Acquisition Regulation (FAR) clause that is published in the 
General Services Administration Acquisition Regulation by the addition 
of ``(DEVIATION (FAR clause no.))'' after the date of the clause.
    (b) Deviations to GSAR clauses: This solicitation indicates any 
authorized deviation to a General Services Administration Acquisition 
Regulation clause by the addition of ``(DEVIATION)'' after the date of 
the clause.
    (c) ``Substantially the same as'' clauses. Changes in wording of 
clauses prescribed for use on a ``substantially the same as'' basis are 
not considered deviations.

                             (End of clause)



Sec. 552.270-1  Instructions to Offerors--Acquisition of Leasehold 
          Interests in Real Property.

    As prescribed in 570.602, insert the following provision:

  Instructions to Offerors--Acquisition of Leasehold Interests in Real 
                           Property (MAR 1998)

    (a) Definitions. As used in this provision--
    ``Discussions'' are negotiations that occur after establishment of 
the competitive range that may, at the contracting Officer's discretion, 
result in the offeror being allowed to revise its proposal.
    ``In Writing'' or ``Written'' means any worded or numbered 
expression which can be read, reproduced, and later communicated, and 
includes electronically transmitted and stored information.
    ``Proposal modification'' is a change made to a proposal before the 
solicitation's closing date and time, or made in response to an 
amendment, or made to correct a mistake at any time before award.
    ``Proposal revision'' is a change to a proposal made after the 
solicitation closing date, at the request of as allowed by a Contracting 
Officer as the result or of negotiations.
    ``Time,'' if stated as a number of days, is calculated using 
calendar days, unless otherwise specified, and will include Saturdays, 
Sundays, and legal holidays. However, if the last day falls on a 
Saturday, Sunday, or legal holiday, then the period shall include the 
next working day.
    (b) Amendments to solicitations. If this solicitation is amended, 
all terms and conditions that are not amended remain unchanged. Offerors 
shall acknowledge receipt of any amendment to this solicitation by the 
date and time specified in the amendment(s).
    (c) Submission, modification, revision, and withdrawal of proposals.
    (1) Unless other methods (e.g., electronic commerce or facsimile) 
are permitted in the solicitation, proposals and modifications to 
proposals shall be submitted in paper media in sealed envelopes or 
packages. Offers must be:
    (i) Submitted on the forms prescribed and furnished by the 
Government as a part of this solicitation or on copies of those forms, 
and
    (ii) Signed. The person signing an offer must initial each erasure 
or change appearing on any offer form. If the offeror is a partnership, 
the names of the partners composing the firm must be included with the 
offer.
    (2) Late proposals and revisions.
    (i) The Government will not consider any proposal received at the 
office designated in the solicitation after the exact time specified for 
receipt of offers unless it is received before the Government makes 
award and it meets at least one of the following conditions:
    (A) It was sent by registered or certified mail not later than the 
5th calendar day before the date specified for receipt of offers

[[Page 263]]

(e.g., an offer submitted in response to solicitation requiring receipt 
of offers by the 20th of the month must have been mailed by the 15th).
    (B) It was sent by mail (or telegram or facsimile, if authorized) or 
hand-carried (including delivery by a commercial carrier) if it is 
determined by the Government that the late receipt was due primarily to 
Government mishandling after receipt at the Government installation.
    (C) It was sent by U.S. Postal Service Express Mail Next Day 
Service-Post Office to Addressee, not later than 5:00 p.m. at the place 
of mailing two working days prior to the date specified for receipt of 
proposals. The term ``working days'' excludes weekends and U.S. Federal 
holidays.
    (D) It was transmitted through an electronic commerce method 
authorized by the solicitation and was received at the initial point of 
entry of the Government infrastructure not later than 5:00 p.m. one 
working day prior to the date specified for receipt of proposals.
    (E) There is acceptable evidence to establish that it was received 
at the activity designated for receipt of offers and was under the 
Government's control prior to the time set for receipt of offers, and 
the Contracting Officer determines that accepting the late offer would 
not unduly delay the procurement.
    (F) It is the only proposal received.
    (ii) Any modification or revision of a proposal or response to 
request for information, including any final proposal revision, is 
subject to the same conditions as in subparagraphs (c)(2)(i)(A) through 
(c)(2)(i)(E) of this provision.
    (iii) The only acceptable evidence to establish the date of mailing 
of a late proposal or modification or revision sent either by registered 
or certified mail is the U.S. or Canadian Postal Service postmark both 
on the envelope or wrapper and on the original receipt from the U.S. or 
Canadian Postal Service. Both postmarks must show a legible date or the 
proposal, response to a request for information, or modification or 
revision shall be processed as if mailed late. ``Postmark'' means a 
printed, stamped, or otherwise placed impression (exclusive of a postage 
meter machine impression) that is readily identifiable without further 
action as having been supplied and affixed by employees of the U.S. or 
Canadian Postal Service on the date of mailing. Therefore, offerors or 
respondents should request the postal clerk to place a legible hand 
cancellation bull's eye postmark on both the receipt and the envelope or 
wrapper.
    (iv) Acceptable evidence to establish the time of receipt at the 
Government installation includes the time/date stamp of that 
installation on the proposal wrapper, other documentary evidence of 
receipt maintained by the installation, or oral testimony or statements 
of Government personnel.
    (v) The only acceptable evidence to establish the date of mailing of 
a late offer, modification or revision, or withdrawal sent by Express 
Mail Next Day Service-Post Office to Addressee is the date entered by 
the post office receiving clerk on the ``Express Mail Next Day Service-
Post Office to Addressee'' label and the postmark on both the envelope 
or wrapper and on the original receipt from the U.S. Postal Service, 
``Postmark'' has the same meaning as defined in paragraph (c)(2)(iii) of 
this provision, excluding postmarks of the Canadian Postal Service. 
Therefore, offerors or respondents should request the postal clerk to 
place a legible hand cancellation bull's eye postmark on both the 
receipt and the envelope or wrapper.
    (vi) Notwithstanding paragraph (c)(2)(i) of this provision, a late 
modification or revision of an otherwise successful proposal that makes 
its terms more favorable to the Government will be considered at any 
time it is received and may be accepted.
    (vii) An offeror may withdraw its proposal by written notice or 
telegram (including mailgram) received at any time before award. If the 
solicitation authorizes facsimile proposals, an offeror may withdraw its 
proposal via facsimile received at any time before award, subject to the 
conditions specified in the provision entitled ``Facsimile Proposals.'' 
Proposals may be withdrawn in person by an offeror or an authorized 
representative, if the representative's identity is made known and the 
representative signs a receipt for the proposal before award.
    (viii) If an emergency or unanticipated event interrupts normal 
Government processes so that proposals cannot be received at the office 
designated for receipt of proposals by the exact time specified in the 
solicitation, and urgent Government requirements preclude amendment of 
the solicitation or other notice of an extension of the closing date, 
the time specified for receipt of proposals will be deemed to be 
extended to the same time of day specified in the solicitation on the 
first work day on which normal Government processes resume. If no time 
is specified in the solicitation, the time for receipt is 4:30 p.m., 
local time, for the designated Government office.
    (3) Any information given to a prospective offeror concerning this 
solicitation will be furnished promptly to all other prospective 
offerors, if that information is necessary in submitting offers or if 
the lack of it would be prejudicial to any other prospective offeror.
    (4) Offerors may submit modifications to their proposals at any time 
before the solicitation closing date and time, and may submit 
modifications in response to an amendment, or to correct a mistake at 
any time before award.

[[Page 264]]

    (5) Offerors may submit revised proposals only if requested or 
allowed by the Contracting Officer.
    (6) The Government will construe an offer to be in full and complete 
with this solicitation unless the offer describes any deviation in the 
offer.
    (7) Offerors may submit proposals that depart from stated 
requirements. Such a proposal shall clearly identify why the acceptance 
of the proposal would be advantageous to the Government. The proposal 
must clearly identify and explicitly define any deviations from the 
terms and conditions of the solicitation, as well as the comparative 
advantage to the Government. The Government reserves the right to amend 
the solicitation to allow all offerors an opportunity to submit revised 
proposals based on the revised requirements.
    (d) Restriction on disclosure and use of data. An offeror that 
includes in its proposal data that it does not want disclosed to the 
public for any purpose, or use by the Government except for evaluation 
purposes, must meet both of the following conditions:
    (1) Mark the title page with the following legend:
    This proposal includes data that shall not be disclosed outside the 
Government and shall not be duplicated, used, or disclosed--in whole or 
in part--for any purpose other than to evaluate this proposal. If, 
however, a lease is awarded to this offeror as a result of--or in 
connection with--the submission of this data, the Government shall have 
the right to duplicate, use, or disclose the data to the extent provided 
in the resulting contract. This restriction does not limit the 
Government's right to use information contained in this data if it is 
obtained from another source without restriction. The data subject to 
this restriction are contained in sheets [insert numbers or other 
identification of sheets].
    (2) Mark each sheet of data it wishes to restrict with the following 
legend:
    Use or disclosure of data contained on this sheet is subject to the 
restriction on the title page of this proposal.
    (e) Lease award.
    (1) The Government intends to award a lease resulting from this 
solicitation to the responsible offeror whose proposal represents the 
best value after evaluation in accordance with the factors and 
subfactors in the solicitation.
    (2) The Government may reject any or all proposals if such action is 
in the Government's interest.
    (3) The Government may waive informalities and minor irregularities 
in proposals received.
    (4) The Government intends to evaluate proposals and award a lease 
after conducting discussions with offerors whose proposals have been 
determined to be within the competitive range. If the Contracting 
Officer determines that the number of proposals that would otherwise be 
in the competitive range exceeds the number at which an efficient 
competition can be conducted, the Contracting Officer may limit the 
number of proposals in the competitive range to the greatest number that 
will permit an efficient competition among the most highly rated 
proposals. Therefore, the offeror's initial proposal should contain the 
offeror's best terms from a price and technical standpoint.
    (5) Exchanges with offerors after receipt of a proposal do not 
constitute a rejection or counteroffer by the Government.
    (6) The Government may determine that a proposal is unacceptable if 
the price proposed are materially unbalanced between line terms or 
subline items. Unbalanced pricing exists when, despite an acceptable 
total evaluated price, the price of one or more contract line items is 
significantly overstated or understand as indicated by the application 
of cost or price analysis techniques. A proposal may be rejected if the 
Contracting Officer determines that the lack of balance poses an 
unacceptable risk to the Government.
    (7) The unconditional written acceptance of an offer establishes a 
valid contract.
    (8) The Government may disclose the following information in 
postaward debriefings to other offerors:
    (i) The overall evaluated cost or price and technical rating of the 
successful offeror;
    (ii) The overall making of all offerors, when any making was 
developed by the agency during source selection; and
    (iii) A summary of the rationale for award.

                           (End of provision)

    Alternate I (MAR 1998). As prescribed in 570.602, substitute the 
following paragraph for paragraph (c)(2)(i) of the basic provision:

    (i) Any offer received at the office designated in the solicitation 
after the exact time specified for receipt of final proposal revisions 
will not be considered unless it is received before award is made and it 
meets one of the following conditions--

    Alternate II (MAR 1998). As prescribed in 570.602, substitute the 
following paragraph for paragraph (e)(4) of the basic provision:

    (4) The Government intends to evaluate proposals and award a lease 
without discussions with offerors (except clarifications as described in 
FAR 15.306(a)). Therefore, the offeror's initial proposal should contain 
the offeror's best terms from a cost or price and technical standpoint. 
The Government reserves the right to conduct discussions if the 
Contracting Officer later determines them to

[[Page 265]]

be necessary. If the Contracting Officer determines that the number of 
proposals that would otherwise be in the competitive range exceeds the 
number at which an efficient competition can be conducted, the 
Contracting Officer may limit the number of proposals in the competitive 
range to the greatest number that will permit an efficient competition 
among the most highly rated proposals.



Sec. 552.270-2  Historic Preference.

    As prescribed in 570.602, insert the following provision:

                     Historic Preference (SEP 1999)

    (a) The Government will give preference to offers of space in 
buildings on, or formally listed as eligible for inclusion in, the 
National Register of Historic Places and to historically significant 
buildings in historic districts listed in the National Register. This 
preference extends to historic buildings and will result in award if 
both of the following are met:
    (1) The offer for space meets the terms and conditions of this 
solicitation as well as any other offer received. The Contracting 
Officer has discretion to accept alternatives to certain architectural 
characteristics and safety features defined elsewhere in this 
solicitation to maintain the historical integrity of the building such 
as high ceilings, wooden floors, etc.
    (2) The rental is no more than 10 percent higher on a total annual 
usable square foot cost to the Government than the lowest otherwise 
acceptable offer.
    (b) If the Government receives more than one offer of an historic 
building and they meet the above criteria, the Government will award to 
the lowest priced historic property offered.

                           (End of provision)



Sec. 552.270-3  Parties to Execute Lease.

    As prescribed in 570.602, insert the following provision:

                   Parties to Execute Lease (SEP 1999)

    (a) If the lease is executed by an attorney, agent, or trustee on 
behalf of the Lessor, an authenticated copy of his power of attorney, or 
other evidence to act on behalf of the Lessor, shall accompany the 
lease.
    (b) If the Lessor is a partnership, the lease shall be signed with 
the partnership name, followed by the name of the legally authorized 
partner signing the same, and, if requested by the Government, a copy of 
either the partnership agreement or current Certificate of Limited 
Partnership shall accompany the lease.
    (c) If the Lessor is a corporation, the lease shall be signed with 
the corporate name, followed by the signature and title of the officer 
or other person signing the lease on its behalf, duly attested, and, if 
requested by the Government, evidence of this authority to so act shall 
be furnished.

                           (End of provision)



Sec. 552.270-4  Definitions.

    As prescribed in 570.603, insert the following clause:

                         Definitions (SEP 1999)

    The following terms and phrases (except as otherwise expressly 
provided or unless the context otherwise requires) for all purposes of 
this lease shall have the respective meanings hereinafter specified:
    (a) ``Commencement Date'' means the first day of the term.
    (b) ``Contract'' and ``Contractor'' means ``Lease'' and ``Lessor,'' 
respectively.
    (c) ``Contracting Officer'' means a person with the authority to 
enter into, administer, and/or terminate contracts and make related 
determinations and findings. The term includes certain authorized 
representatives of the Contracting Officer acting within the limits of 
their authority as delegated by the Contracting Officer.
    (d) ``Delivery Date'' means the date specified in or determined 
pursuant to the provisions of this lease for delivery of the premises to 
the Government, improved in accordance with the provisions of this lease 
and substantially complete, as such date may be modified in accordance 
with the provisions of this lease.
    (e) ``Delivery Time'' means the number of days provided by this 
lease for delivery of the premises to the Government, as such number may 
be modified in accordance with the provision so this lease.''
    (f) ``Excusable Delays'' means delays arising without the fault or 
negligence of Lessor and Lessor's subcontractors and suppliers at any 
tier, and shall include, without limitation:
    (1) acts of God or of the public enemy,
    (2) acts of the United States of America in either its sovereign or 
contractual capacity,
    (3) acts of another contractor in the performance of a contract with 
the Government,
    (4) fires,
    (5) floods,
    (6) epidemics,
    (7) quarantine restrictions,
    (8) strikes,
    (9) freight embargoes,
    (10) unusually severe weather, or
    (11) delays of subcontractors or suppliers at any tier arising from 
unforeseeable causes beyond the control and without the fault or

[[Page 266]]

negligence of both the Lessor and any such subcontractor or supplier.
    (g) ``Lessor'' means the sub-lessor if this lease is a sublease.
    (h) ``Lessor shall provide'' means the Lessor shall furnish and 
install at Lessor's expense.
    (i) ``Notice'' means written notice sent by certified or registered 
mail, Express Mail or Comparable service, or delivered by hand. Notice 
shall be effective on the date delivery is accepted or refused.
    (j) ``Premises'' means the space described in this lease.
    (k) ``Substantially complete'' and ``substantial completion'' means 
that the work, the common and other areas of the building, and all other 
things necessary for the Government's access to the premises and 
occupancy, possession, use and enjoyment thereof, as provided in this 
lease, have been completed or obtained, excepting only such minor 
matters as do not interfere with or materially diminish such access, 
occupancy, possession, use of enjoyment.
    (l) ``Usable square feet'' means the ANSI/BOMA Z65.1-1996 definition 
for BOMA usable office area, which means ``The area where a tenant 
normally houses personnel and/or furniture, for which a measurement is 
to be computed.''
    (m) ``Work'' means all alterations, improvements, modifications, and 
other things required for the preparation or continued occupancy of the 
premises by the Government as specified in this lease.

                             (End of clause)



Sec. 5512.270-5  Subletting and Assignment.

    As prescribed in 570.603, insert the following clause:

                  Subletting and Assignment (SEP 1999)

    The Government may sublet any part of the premises but shall not be 
relieved from any obligations under this lease by reason of any such 
subletting. The Government may at any time assign this lease, and be 
relieved from all obligations to Lessor under this lease excepting only 
unpaid rent and other liabilities, if any that have accrued to the date 
of said assignment. Any assignment shall be subject to prior written 
consent of Lessor, which shall not be unreasonably withheld.

                             (End of clause)



Sec. 552.270-6  Maintenance of Building and Premises--Right of Entry.

    As prescribed in 570.603, insert the following clause:

     Maintenance of Building and Premises--Right of Entry (SEP 1999)

    Except in case of damage arising out of the willful act or 
negligence of a Government employee, Lessor shall maintain the premises, 
including the building and all equipment, fixtures, and appurtenances 
furnished by the lessor under this lease, in good repair and condition 
so that they are suitable in appearance and capable of supplying such 
heat, air conditioning, light, ventilation, access and other things to 
the premises, without reasonably preventable or recurring disruption, as 
is required for the Government's access to, occupancy, possession, use 
and enjoyment of the premises as provided in this lease. For the purpose 
of so maintaining the premises, the Lessor may at reasonable times enter 
the premises with the approval of the authorized Government 
representative in charge.

                             (End of clause)



Sec. 552.270-7  Fire and Casualty Damage.

    As prescribed in 570.603, insert the following clause:

                   Fire and Casualty Damage (SEP 1999)

    If the entire premises are destroyed by fire or other casualty, this 
lease will immediately terminate. In case of partial destruction or 
damage, so as to render the premises untenantable, as determined by the 
Government, the Government may terminate the lease by giving written 
notice to the Lessor within 15 calendar days of the fire or other 
casualty; if so terminated, no rent will accrue to the Lessor after such 
partial destruction or damage; and if not so terminated, the rent will 
be reduced proportionately by supplemental agreement hereto effective 
from the date of such partial destruction or damage. Nothing in this 
lease shall be construed as relieving Lessor from liability for damage 
to or destruction of property of the United States of America caused by 
the willful or negligent act or omission of Lessor.

                             (End of clause)



Sec. 552.270-8  Compliance with Applicable Law.

    As prescribed in 570.603, insert the following clause:

                Compliance With Applicable Law (SEP 1999)

    Lessor shall comply with all Federal, state and local laws 
applicable to the Lessor as owner or lessor, or both, of the building or 
premises, including, without limitation, laws applicable to the 
construction, ownership, alteration or operation of both or either

[[Page 267]]

thereof, and will obtain all necessary permits, licenses and similar 
items at Lessor's expense. The Government will comply with all Federal, 
state and local laws applicable to and enforceable against it as a 
tenant under this lease; provided that nothing in this lease shall be 
construed as a waiver of any sovereign immunity of the Government. This 
lease shall be governed by Federal law.

                             (End of clause)



Sec. 552.270-9  Inspection--Right of Entry.

    As prescribed in 570.603, insert the following clause:

                  Inspection--Right of Entry (SEP 1999)

    (a) At any time and from time to time after receipt of an offer 
(until the same has been duly withdrawn or rejected), after acceptance 
thereof and during the term, the agents, employees and contractors of 
the Government may, upon reasonable prior notice to Offeror or Lessor, 
enter upon the offered premises or the premises, and all other areas of 
the building access to which is necessary to accomplish the purposes of 
entry, to determine the potential or actual compliance by the Offeror or 
Lessor with the requirements of the solicitation or this lease, which 
purposes shall include, but not be limited to:
    (1) Inspecting, sampling and analyzing suspected asbestos-containing 
materials and air monitoring for asbestos fibers;
    (2) Inspecting the heating, ventilation and air conditioning system, 
maintenance records, and mechanical rooms for the offered premises or 
the premises;
    (3) Inspecting for any leaks, spills, or other potentially hazardous 
conditions which may involve tenant exposure to hazardous or toxic 
substances; and
    (4) Inspecting for any current or past hazardous waste operations, 
to ensure that appropriate mitigative actions were taken to alleviate 
any environmentally unsound activities in accordance with Federal, State 
and local law.
    (b) Nothing in this clause shall be construed to create a Government 
duty to inspect for toxic materials or to impose a higher standard of 
care on the Government than on other lessees. The purpose of this clause 
is to promote the ease with which the Government may inspect the 
building. Nothing in this clause shall act to relieve the Lessor of any 
duty to inspect or liability which might arise as a result of Lessor's 
failure to inspect for or correct a hazardous condition.

                             (End of clause)



Sec. 552.270-10  Failure in Performance.

    As prescribed in 570.603, insert the following clause:

                    Failure in Performance (SEP 1999)

    The covenant to pay rent and the covenant to provide any service, 
utility, maintenance, or repair required under this lease are 
interdependent. In the event of any failure by the Lessor to provide any 
service, utility, maintenance, repair or replacement required under this 
lease the Government may, by contract or otherwise, perform the 
requirement and deduct from any payment or payments under this lease, 
then or thereafter due, the resulting cost to the Government, including 
all administrative costs. If the Government elects to perform any such 
requirement, the Government and each of its contractors shall be 
entitled to access to any and all areas of the building, access to which 
is necessary to perform any such requirement, and the Lessor shall 
afford and facilitate such access. Alternatively, the Government may 
deduct from any payment under this lease, then or thereafter due, an 
amount which reflects the reduced value of the contract requirement not 
performed. No deduction from rent pursuant to this clause shall 
constitute a default by the Government under this lease. These remedies 
are not exclusive and are in addition to any other remedies which may be 
available under this lease or at law.

                             (End of clause)



Sec. 552.270-11  Successors Bound.

    As prescribed in 570.603, insert the following clause:

                       Successors Bound (SEP 1999)

    This lease shall bind, and inure to the benefit of, the parties and 
their respective heirs, executors, administrators, successors and 
assigns.

                             (End of clause)



Sec. 552.270-12  Alterations.

    As prescribed in 570.603, insert the following clause:

                         Alterations (SEP 1999)

    The Government shall have the right during the existence of this 
lease to make alterations, attach fixtures, and erect structures or 
signs in or upon the premises hereby leased, which fixtures, additions 
or structures so placed in, on, upon, or attached to

[[Page 268]]

the said premises shall be and remain the property of the Government and 
may be removed or otherwise disposed of by the Government. If the lease 
contemplates that the Government is the sole occupant of the building, 
for purposes of this clause, the leased premises include the land on 
which the building is sited and the building itself. Otherwise, the 
Government shall have the right to tie into or make any physical 
connection with any structure located on the property as is reasonably 
necessary for appropriate utilization of the leased space.

                             (End of clause)



Sec. 552.270-13  Proposals for Adjustment.

    As prescribed in 570.603, insert the following clause:

                   Proposals for Adjustment (SEP 1999)

    (a) The Contracting Officer may, from time to time during the term 
of this lease, require changes to be made in the work or services to be 
performed and in the terms or conditions of this lease. Such changes 
will be required under the Changes clause.
    (b) If the Contracting Officer makes a change within the general 
scope of the lease, the Lessor shall submit, in a timely manner, an 
itemized cost proposal for the work to be accomplished or services to be 
performed when the cost exceeds $100,000. The proposal, including all 
subcontractor work, will contain at least the following details--
    (1) Material quantities and unit costs;
    (2) Labor costs (identified with specific item or material to be 
placed or operation to be performed);
    (3) Equipment costs;
    (4) Worker's compensation and public liability insurance;
    (5) Overhead;
    (6) Profit; and
    (7) Employment taxes under FICA and FUTA.
    (c) The following Federal Acquisition Regulation (FAR) provisions 
also apply to all proposals exceeding $500,000 in cost--
    (1) The Lessor shall provide cost or pricing data including 
subcontractor cost or pricing data (48 CFR 15.403-4); and
    (2) The Lessor's representative, all Contractors, and subcontractors 
whose portion of the work exceeds $500,000 must sign and return the 
``Certificate of Current Cost or Pricing Data'' (48 CFR 15.406-2).
    (d) Lessors shall also refer to 48 CFR Part 31, Contract Cost 
Principles, for information on which costs are allowable, reasonable, 
and allocable in Government work.

                             (End of clause)



Sec. 552.270-14  Changes.

    As prescribed in 570.603, insert the following clause:

                           Changes (SEP 1999)

    (a) The Contracting Officer may at any time, by written order, make 
changes within the general scope of this lease in any one or more of the 
following:
    (1) Specifications (including drawings and designs).
    (2) Work or services.
    (3) Facilities or space layout.
    (4) Amount of space, provided the Lessor consents to the change.
    (b) If any such change causes an increase or decrease in Lessor's 
cost of or the time required for performance under this lease, whether 
or not changed by the order, the Contracting Officer shall modify this 
lease to provide for one or more of the following:
    (1) A modification of the delivery date.
    (2) An equitable adjustment in the rental rate.
    (3) A lump sum equitable adjustment.
    (4) An equitable adjustment of the annual operating costs per usable 
square foot specified in this lease.
    (c) The Lessor must assert its right to an adjustment under this 
clause within 30 days from the date of receipt of the change order and 
must submit a proposal for adjustment. Failure to agree to any 
adjustment shall be a dispute under the Disputes clause. However, 
nothing in this clause excuses the lessor from proceeding with the 
change as directed.
    (d) Absent such written change order, the Government is not liable 
to Lessor under this clause.

                             (End of clause)



Sec. 552.270-15  Liquidated Damages.

    As prescribed in 570.603, insert the following clause:

                      Liquidated Damages (SEP 1999)

    In case of failure on the part of the Lessor to complete the work 
within the time fixed in the lease contract or letter of award, the 
Lessor shall pay the Government as fixed and agreed liquidated damages, 
pursuant to this clause, the sum $___ for each and every calendar day 
that the delivery is delayed beyond the date specified for delivery of 
all the space ready for occupancy by the Government. this remedy is not 
exclusive and is in addition to any other remedies which may be 
available under this lease or at law.


[[Page 269]]



                             (End of clause)



Sec. 552.270-16  Adjustment for Vacant Premises.

    As prescribed in 570.603, insert the following clause:

                Adjustment for Vacant Premises (SEP 1999)

    (a) If the Government fails to occupy any portion of the leased 
premises or vacates the premises in whole or in part before the lease 
term expires, the rental rate will be reduced.
    (b) The rental rate will be reduced by that portion of the costs per 
usable square foot of operating expenses not required to maintain the 
space. The reduction takes effect 30 calendar days after the Government 
gives notice to the Lessor, and continues in effect until the Government 
occupies the premises or the lease expires or is terminated.

                             (End of clause)



Sec. 552.270-17  Delivery and Condition.

    As prescribed in 570.603, insert the following clause:

                    Delivery and Condition (SEP 1999)

    (a) Unless the Government elects to have the space occupied in 
increments, the space must be delivered ready for occupancy as a 
complete unit. The Government reserves the right to determine when the 
space is substantially complete.
    (b) If the premises do not in every respect comply with the 
provisions of this lease the Contracting Officer may, in accordance with 
the Failure in Performance clause of this lease, elect to reduce the 
rent payments.

                             (End of clause)



Sec. 552.270-18  Default in Delivery--Time Extensions.

    As prescribed in 570.603, insert the following clause:

             Default In Delivery--Time Extensions (SEP 1999)

    (a) With respect to Lessor's obligation to deliver the premises 
substantially complete by the delivery date, time is of the essence. If 
the Lessor fails to work diligently to ensure its substantial completion 
by the delivery date or fails to substantially complete the work by such 
date, the Government may by notice to the Lessor terminate this lease. 
Such termination is effective when received by Lessor. The Lessor and 
the Lessor's sureties, if any, are jointly and severally liable for any 
damages to the Government resulting from such termination, as provided 
in this clause. The Government is entitled to the following damages:
    (1) The Government's aggregate rent, estimated real estate tax, and 
operating cost adjustments for the firm term and all option terms of its 
replacement lease or leases, in excess of the aggregate rent and 
estimated real estate tax and operating cost adjustments for the term. 
If the Government procures replacement premises for a term (including 
all option terms) in excess of this lease term, the Lessor is not liable 
for excess Government rent or adjustments during such excess lease term.
    (2) All administrative and other costs the Government incurs in 
procuring a replacement lease or leases.
    (3) Other, additional relief provided for in this lease, at law, or 
in equity.
    (b) Damages to which the Government is entitled under this clause 
are due and payable thirty (30) days following the date Lessor receives 
notice from the Contracting Officer specifying such damages.
    (c) Delivery by Lessor of less than the minimum usable square 
footage required by this lease shall in no event be construed as 
substantial completion, except as the Contracting Officer permits.
    (d) The Government shall not terminate this lease under this clause 
nor charge the Lessor with damages under this clause, if (1) the delay 
in substantially completing the work arises from excusable delays, and 
(2) the Lessor within 10 days from the beginning of any such delay 
(unless extended in writing by the Contracting Officer) provides notice 
to the Contracting Officer of the causes of delay. The Contracting 
Officer shall ascertain the facts and the extent of delay. If the facts 
warrant, the Contracting Officer shall extend the delivery date, to the 
extent of such delay at no additional costs to the Government. A time 
extension is the sole remedy of the Lessor.

                             (End of clause)



Sec. 552.270-19  Progressive Occupancy.

    As prescribed in 570.603, insert the following clause:

                    Progressive Occupancy (SEP 1999)

    The Government shall have the right to elect to occupy the space in 
partial increments prior to the substantial completion of the entire 
leased premises, and the Lessor agrees to schedule its work so as to 
deliver the space incrementally as elected by the Government. The 
Government shall pay rent commencing with the first business day 
following substantial completion of the entire leased premise unless the 
Government has elected to occupy the leased premises incrementally. In 
case of incremental occupancy, the Government shall pay rent pro rata 
upon

[[Page 270]]

the first business day following substantial completion of each 
incremental unit. Rental payments shall become due on the first workday 
of the month following the month in which an increment of space is 
substantially complete, except that should an increment of space be 
substantially completed after the fifteenth day of the month, the 
payment due date will be the first workday of the second month following 
the month in which it was substantially complete. The commencement date 
of the firm lease term will be a complete determined from all rent 
commencement dates.

                             (End of clause)



Sec. 552.270-20  Payment.

    As prescribed in 570.603, insert the following clause:

                           Payment (SEP 1999)

    (a) When space is offered and accepted, usable square footage 
delivered will be confirmed by either:
    (1) The Government's measurement of plans submitted by the 
successful offeror as approved by the Government, and an inspection of 
the space to verify that the delivered space conforms with such plans.
    (2) A mutual on-site measurement of the space if the Contracting 
Officer determines it necessary.
    (b) The Government will not pay for space in excess of the amount of 
usable square footage stated in the lease.
    (c) If the amount of usable square footage delivered is less than 
the amount agreed to in the lease, the lease will be modified to reflect 
the amount of usable space delivered and the annual rental will be 
adjusted as follows:
    Usable square feet (USF) not delivered multiplied by one plus the 
common area factor (CAF), multiplied by the rate per rentable square 
foot (RSF). That is:

          USF X(1+CAF) X Rate per RSF=Reduction in Annual Rent.

                             (End of clause)



Sec. 552.270-21  Effect of Acceptance and Occupancy.

    As prescribed in 570.603, insert the following clause:

              Effect of Acceptance and Occupancy (SEP 1999)

    Neither the Government's acceptance of the premises for occupancy, 
nor the Government's occupancy thereof, shall be construed as a waiver 
of any requirement of or right of the Government under this Lease, or as 
otherwise prejudicing the Government with respect to any such 
requirement or right.

                             (End of clause)



Sec. 552.270-22  Default by Lessor During the Term.

    As prescribed in 570.603, insert the following clause:

              Default By Lessor During the Term (SEP 1999)

    (a) Each of the following shall constitute a default by Lessor under 
this lease:
    (1) Failure to maintain, repair, operate or service the premises as 
and when specified in this lease, or failure to perform any other 
requirement of this lease as and when required provided any such failure 
shall remain uncured for a period of thirty (30) days next following 
Lessor's receipt of notice thereof from the Contracting Officer or an 
authorized representative.
    (2) Repeated and unexcused failure by Lessor to comply with one or 
more requirements of this lease shall constitute a default 
notwithstanding that one or all such failures shall have been timely 
cured pursuant to this clause.
    (b) If a default occurs, the Government may, by notice to Lessor, 
terminate this lease for default and if so terminated, the Government 
shall be entitled to the damages specified in the Default in Delivery-
Time Extensions clause.

                             (End of clause)



Sec. 552.270-23  Subordination, Nondisturbance and Attornment.

    As prescribed in 570.603, insert the following clause:

         Subordination, Nondisturbance and Attornment (SEP 1999)

    (a) Lessor warrants that it holds such title to or other interest in 
the premises and other property as is necessary to the Government's 
access to the premises and full use and enjoyment thereof in accordance 
with the provisions of this lease. Government agrees, in consideration 
of the warranties and conditions set forth in this clause, that this 
lease is subject and subordinate to any and all recorded mortgages, 
deeds of trust and other liens now or hereafter existing or imposed upon 
the premises, and to any renewal, modification or extension thereof. It 
is the intention of the parties that this provision shall be self-
operative and that no further instrument shall be required to effect the 
present or subsequent subordination of this lease. Government agrees, 
however, within twenty (20) business days next following the Contracting 
Officer's receipt of a

[[Page 271]]

written demand, to execute such instruments as Lessor may reasonably 
request to evidence further the subordination of this lease to any 
existing or future mortgage, deed of trust or other security interest 
pertaining to the premises, and to any water, sewer or access easement 
necessary or desirable to serve the premises or adjoining property owned 
in whole or in part by Lessor if such easement does not interfere with 
the full enjoyment of any right granted the Government under this lease.
    (b) No such subordination, to either existing or future mortgages, 
deeds of trust or other lien or security instrument shall operate to 
affect adversely any right of the Government under this lease so long as 
the Government is not in default under this lease. Lessor will include 
in any future mortgage, deed of trust or other security instrument to 
which this lease becomes subordinate, or in a separate nondisturbance 
agreement, a provision to the foregoing effect. Lessor warrants that the 
holders of all notes or other obligations secured by existing mortgages, 
deeds of trust or other security instruments have consented to the 
provisions of this clause, and agrees to provide true copies of all such 
consents to the Contracting Officer promptly upon demand.
    (c) In the event of any sale of the premises or any portion thereof 
by foreclosure of the lien of any such mortgage, deed of trust or other 
security instrument, or the giving of a deed in lieu of foreclosure, the 
Government will be deemed to have attorned to any purchaser, purchasers, 
transferee or transferees of the premises or any portion thereof and its 
or their successors and assigns, and any such purchasers and transferees 
will be deemed to have assumed all obligations of the Lessor under this 
lease, so as to establish direct privity of estate and contract between 
Government and such purchasers or transferees, with the same force, 
effect and relative priority in time and right as if the lease had 
initially been entered into between such purchasers or transferees and 
the Government; provided, further, that the Contracting Officer and such 
purchasers or transferees shall, with reasonable promptness following 
any such sale or deed delivery in lieu of foreclosure, execute all such 
revisions to this lease, or other writings, as shall be necessary to 
document the foregoing relationship.
    (d) None of the foregoing provisions may be deemed or construed to 
imply a waiver of the Government's rights as a sovereign.

                             (End of clause)



Sec. 552.270-24  Statement of Lease.

    As prescribed in 570.603, insert the following clause:

                      Statement of Lease (SEP 1999)

    (a) The Contracting Officer will, within thirty (30) days next 
following the Contracting Officer's receipt of a joint written request 
from Lessor and a prospective lender or purchaser of the building, 
execute and deliver to Lessor a letter stating that the same is issued 
subject to the conditions stated in this clause and, if such is the 
case, that (1) the lease is in full force and effect; and (2) the date 
to which the rent and other charges have been paid in advance, if any; 
and (3) whether any notice of default has been issued.
    (b) Letters issued pursuant to this clause are subject to the 
following conditions:
    (1) That they are based solely upon a reasonably diligent review of 
the Contracting Officer's lease file as of the date of issuance;
    (2) That the Government shall not be held liable because of any 
defect in or condition of the premises or building;
    (3) That the Contracting Officer does not warrant or represent that 
the premises or building comply with applicable Federal, State and local 
law; and
    (4) That the Lessor, and each prospective lender and purchaser are 
deemed to have constructive notice of such facts as would be 
ascertainable by reasonable prepurchase and precommitment inspection of 
the Premises and Building and by inquiry to appropriate Federal, State 
and local Government officials.

                             (End of clause)



Sec. 552.270-25  Substitution of Tenant Agency.

    As prescribed in 570.603, insert the following clause:

                Substitution of Tenant Agency (SEP 1999)

    The Government may, at any time and from time to time, substitute 
any Government agency or agencies for the Government agency or agencies, 
if any, named in the lease.

                             (End of clause)



Sec. 552.270-26  No Waiver.

    As prescribed in 570.603, insert the following clause:

                          No Waiver (SEP 1999)

    No failure by either party to insist upon the strict performance of 
any provision of this lease or to exercise any right or remedy 
consequent upon a breach thereof, and no acceptance of full or partial 
rent or other performance by either party during the continuance of any 
such breach shall constitute a waiver of any such breach of such 
provision.


[[Page 272]]



                             (End of clause)



Sec. 552.270-27  Integrated Agreement.

    As prescribed in 570.603, insert the following clause:

                     Integrated Agreement (SEP 1999)

    This Lease, upon execution, contains the entire agreement of the 
parties and no prior written or oral agreement, express or implied, 
shall be admissible to contradict the provisions of the Lease.

                             (End of clause)



Sec. 552.270-28  Mutuality of Obligation.

    As prescribed in 570.603, insert the following clause:

                   Mutuality of Obligation (SEP 1999)

    The obligations and covenants of the Lessor, and the Government's 
obligation to pay rent and other Government obligations and covenants, 
arising under or related to this Lease, are interdependent. The 
Government may, upon issuance of and delivery to Lessor of a final 
decision asserting a claim against Lessor, set off such claim, in whole 
or in part, as against any payment or payments then or thereafter due 
the Lessor under this lease. No setoff pursuant to this clause shall 
constitute a breach by the Government of this lease.

                             (End of clause)



Sec. 552.270-29  Acceptance of Space.

    As prescribed in 570.603, insert the following clause:

                     Acceptance of Space (SEP 1999)

    (a) When the Lessor has completed all alterations, improvements, and 
repairs necessary to meet the requirements of the lease, the Lessor 
shall notify the Contracting Officer. The Contracting Officer or 
designated representative shall promptly inspect the space.
    (b) The Government will accept the space and the lease term will 
begin after determining that the space is substantially complete and 
contains the required usable square footage as indicated in Paragraph 
1.1, Amount and Type of Space, of this solicitation.

                             (End of clause)

                             PART 553 FORMS

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37265, July 9, 1999, unless otherwise noted.

                  Subpart 553.2_Illustrations of Forms



Sec. 553.300  Scope of subpart.

    Standard and GSA forms prescribed or referenced in the text of this 
chapter are illustrated in and made a part of the General Services 
Administration Acquisition Manual. The forms are not illustrated in 
Title 48, Chapter 5, of the Code of Federal Regulations. Copies may be 
obtained from the Director of the Office of GSA Acquisition Policy 
(MVP), 1800 F Street, NW, Washington, DC 20405.

[[Page 273]]



                SUBCHAPTER I_SPECIAL CONTRACTING PROGRAMS

         PART 570 ACQUIRING LEASEHOLD INTERESTS IN REAL PROPERTY

                          Subpart 570.1_General

Sec.

Sec. 570.101  Applicability.

Sec. 570.102  Definitions.

Sec. 570.103  Authority to lease.

Sec. 570.104  Competition.

Sec. 570.105  Methods of contracting.

Sec. 570.105-1  Contracting by negotiation.

Sec. 570.105-2  Two-phase design-build selection procedures.

Sec. 570.105-3  Sealed bidding.

Sec. 570.106  Publicizing/Advertising.

Sec. 570.107  Oral presentations.

Sec. 570.108  Responsibility determination.

Sec. 570.109  Certifications.

Sec. 570.110  Cost or pricing data and information other than cost or 
          pricing data.

Sec. 570.111  Inspection and acceptance.

Sec. 570.112  Awards to Federal employees.

Sec. 570.113  Disclosure of mistakes after award.

Sec. 570.114  Protests.

          Subpart 570.2_Simplified Lease Acquisition Procedures


Sec. 570.201  Purpose.

Sec. 570.202  Policy.

Sec. 570.203  Procedures.

Sec. 570.203-1  Market survey.

Sec. 570.203-2  Competition.

Sec. 570.203-3  Soliciting offers.

Sec. 570.203-4  Negotiations, evaluation, and award.

  Subpart 570.3_Contracting Procedures for Leasehold Interests in Real 
                                Property


Sec. 570.301  Market survey.

Sec. 570.302  Description of requirements.

Sec. 570.303  Solicitation for offers.

Sec. 570.303-1  Preparing the SFO.

Sec. 570.303-2  Issuing the SFO.

Sec. 570.303-3  Late offers, modifications of offers, and withdrawals of 
          offers.

Sec. 570.303-4  Changes to SFOs.

Sec. 570.304  General source selection procedures.

Sec. 570.305  Two-phase design-build selection procedures.

Sec. 570.306  Evaluating offers.

Sec. 570.307  Negotiations.

Sec. 570.308  Award.

Sec. 570.309  Debriefings.

    Subpart 570.4_Special Aspects of Contracting for Continued Space 
                              Requirements


Sec. 570.401  Renewal options.

Sec. 570.402  Succeeding leases.

Sec. 570.402-1  General.

Sec. 570.402-2  Publicizing/Advertising.

Sec. 570.402-3  Market survey.

Sec. 570.402-4  No potential acceptable locations.

Sec. 570.402-5  Potential acceptable locations.

Sec. 570.402-6  Cost-benefit analysis.

Sec. 570.403  Expansion requests.

Sec. 570.404  Superseding leases.

Sec. 570.405  Lease extensions.

   Subpart 570.5_Special Aspects of Contracting for Lease Alterations


Sec. 570.501  General.

Sec. 570.502  Alterations by the lessor.

Sec. 570.502-1  Justification and approval requirements.

Sec. 570.502-2  Procedures.

Sec. 570.503  Alterations by the Government or through a separate 
          contract.

       Subpart 570.6_Solicitation Provisions and Contract Clauses


Sec. 570.601  FAR provisions and clauses.

Sec. 570.602  GSAR solicitation provisions.

Sec. 570.603  GSAR contract clauses.

Sec. 570.604  Deviations to provisions and clauses.

                           Subpart 570.7_Forms


Sec. 570.701  Standard forms.

Sec. 570.702  GSA forms.

    Authority: 40 U.S.C. 486(c).

    Source: 64 FR 37265, July 9, 1999, unless otherwise noted.

                          Subpart 570.1_General



Sec. 570.101  Applicability.

    (a) This part applies to acquisitions of leasehold interests in real 
property except:
    (1) Leasehold interests acquired by the power of eminent domain or 
by donation.
    (2) Acquisition of leasehold interests in bare or unimproved land.
    (b) In addition, the GSAR rules in the following table apply. Other 
provisions of 48 CFR Chapter 5 (GSAR) do not apply to leases of real 
property unless specifically cross-referenced in this part 570.

  GSAR Rules Applicable to Acquisitions of Leasehold Interests in Real
                                Property
 
 
 
501               514.201-7(b)          517.207          533
502               514.407               519.7            536.271

[[Page 274]]

 
503               515.204-1             519.12           537.2
504.5             515.209-70            522.8            552
505               515.305               532.1            553
509.4             517.202               532.908          ...............
 



Sec. 570.102  Definitions.

    Acquisition means the acquiring by lease of an interest in improved 
real property for use by the Federal Government, whether the space 
already exists or must be constructed.
    Contract means lease.
    Contractor means lessor.
    Landlord or lessor means any individual, firm, partnership, trust, 
association, State or local government, or other legal entity that 
leases real property to the Government.
    Lease or leasehold interest in real property means a conveyance to 
the Government of the right of exclusive possession of real property for 
a definite period of time by a landlord. It may include operational 
services provided by the landlord.
    Lessee or tenant means the United States of America.
    Operational services means services that support use of a leased 
property, such as heating, ventilation, air condition, utilities, and 
custodial services.
    Rent and related services means that consideration paid for the use 
of leased property plus the costs of operational services whether 
furnished by the lessor, the Government, or both.
    Simplified lease acquisition procedures mean the procedures for 
awarding leases at or below the simplified lease acquisition threshold.
    Simplified lease acquisition threshold Means $100,000 average annual 
rent for the term of the lease, including option periods and excluding 
the cost of operational services.
    Small business means a concern including affiliates, which is 
organized for profit, is independently-owned and operated, is not 
dominant in the field of leasing commercial real estate, and has annual 
average gross receipts of $15 million or less for the preceding three 
fiscal years.
    Solicitation for Offers (SFO) means invitation for bids in sealed 
bidding or request for proposals in negotiations.
    Space in buildings means the premises leased, or to be leased, 
including improvements. Its quantity is normally expressed in square 
feet. It does not include space acquired by the power of eminent domain, 
donation, or condemnation, nor acquisitions of bare or unimproved land.
    Substantially as follows or substantially the same as, when used in 
prescribing a provision or clause, means that you may prepare and use a 
variation of that provision or clause to accommodate requirements 
peculiar to an individual acquisition. The variation must include the 
salient features of the FAR or GSAR provision or clause. It must also be 
consistent with the intent, principle, and substance of the FAR or GSAR 
provision or clause and related coverage on the subject matter.



Sec. 570.103  Authority to lease.

    (a) The Federal Property and Administrative Services Act of 1949 (40 
U.S.C. 490(h)(1)), as amended, and Section 1 of the Reorganization Plan 
No. 18 of 1950 (40 U.S.C. 490 Note) authorize the Administrator of 
General Services to acquire leasehold interests in real property for use 
by Federal agencies. The authority is limited to leases for buildings 
and improvement that bind the Government for periods not exceeding 20 
years.
    (b) You have exclusive authority to enter into and administer leases 
on the Government's behalf to the extent provided in your certificate of 
appointment as a contracting officer.



Sec. 570.104  Competition.

    Unless you use the simplified procedures in subpart 570.2, the 
competition requirements of FAR part 6 apply to acquisition of leasehold 
interests in real property.



Sec. 570.105  Methods of contracting.



Sec. 570.105-1  Contracting by negotiation.

    Contracting by negotiation is usually appropriate for acquiring 
space in a building through a lease contract. You will usually need to 
conduct discussions with offerors about their proposals and consider 
factors other than price in making the award.

[[Page 275]]



Sec. 570.105-2  Two-phase design-build selection procedures.

    Unless you use another acquisition procedure authorized by law, you 
must use the two-phase design-build selection procedures in section 303M 
of the Federal Property and Administrative Services Act of 1949, as 
amended, for lease construction projects. This includes lease 
construction projects with options to purchase the real property leased. 
Use the procedures in section 303M when you meet the conditions in 
paragraphs (a) and (b) of this section:
    (a) You anticipate the lease will involve the design and 
construction of a public building, facility, or work for lease to the 
Government.
    (b) You determine the procedures are appropriate for entering into a 
lease construction contract based on the following:
    (1) You expect to receive three or more offers.
    (2) Offerors will need to perform design work before developing a 
price.
    (3) Offerors will incur a substantial amount of expense in preparing 
offers.
    (4) You consider criteria such as the following:
    (i) The extent to which the project requirements have been 
adequately defined.
    (ii) The time constraints for delivery of the project.
    (iii) The capability and experience of potential contractors.
    (iv) The suitability of the project for use of the two-phase 
selection procedures.
    (v) The capability of the agency to manage the two-phase selection 
process.
    (vi) Other criteria established by the HCA.



Sec. 570.105-3  Sealed bidding.

    For sealed bidding, use the procedures in FAR part 14. In most cases 
you should not use sealed bidding to acquire space in buildings unless 
you meet all the following conditions:
    (a) You have a preselected site.
    (b) A building will be constructed on the site using Government 
furnished plans and specifications.
    (c) The Government will lease the building.



Sec. 570.106  Publicizing/Advertising.

    (a) Subparts 505.101, 505.202, and 505.203 define requirements for 
publicizing lease actions.
    (b) Instead of issuing separate advertisements for multiple, known 
leasing actions, you may include the actions in one consolidated 
advertisement.



Sec. 570.107  Oral presentations.

    You may use oral presentations for acquisitions of leasehold 
interests in real property. Follow the procedures in FAR 15.102.



Sec. 570.108  Responsibility determination.

    (a) Determine that the prospective awardee is responsible with 
respect to the lease under consideration. The standards in FAR 9.104 
apply. As part of the determination that a prospective contractor is 
otherwise qualified and eligible for award, review the List of Parties 
Excluded from Federal Procurement and Nonprocurement Programs.
    (b) Your signature on the contract is deemed an affirmative 
determination.
    (c) If you find an offeror nonresponsible, sign and place in the 
contract file a determination of nonresponsibility. State the basis for 
the determination.
    (d) If you find a small business concern nonresponsible, the 
procedures at FAR 19.6 apply. Place all documents and reports supporting 
a determination of responsibility or nonresponsibility in the lease 
file.



Sec. 570.109  Certifications.

    Before awarding a lease, review applicable certifications for 
compliance with statute and regulations.



Sec. 570.110  Cost or pricing data and information other than cost or 
          pricing data.

    (a) The policies and procedures of FAR 15.403 apply to lease 
contract actions.
    (b) FAR 15.403-1 defines exceptions to and waivers for submitting 
cost or pricing data. Most leasing actions will have adequate price 
competition. For price analysis, you may use a market survey or an 
appraisal conducted using accepted real property appraisal procedures to 
establish a market price for comparison.

[[Page 276]]

    (c) In exceptional cases, the requirement for submission of 
certified cost or pricing data may be waived under FAR 15.403-1(c)(4).
    (d) If cost or pricing data are required, follow the procedures in 
FAR 15.403-4 and 15.406-2.



Sec. 570.111  Inspection and acceptance.

    Before you accept space, obtain an inspection to ensure that the 
space complies with the Government's requirements and specifications. 
Document the inspection and acceptance in the contract file.



Sec. 570.112  Awards to Federal employees.

    If you receive an offer from an officer or employee of the 
Government, follow the procedures in FAR 3.6.



Sec. 570.113  Disclosure of mistakes after award.

    If you discover a mistake in a lessor's offer after award, follow 
the procedures in FAR 14.407-4 and subpart 514.407-4.



Sec. 570.114  Protests.

    FAR 33.1 and 533.1 apply to protests of lease acquisitions.

          Subpart 570.2_Simplified Lease Acquisition Procedures



Sec. 570.201  Purpose.

    This subpart prescribes simplified procedures for small leases. 
These procedures reduce administrative costs, while improving efficiency 
and economy, when acquiring small leasehold interests in real property.



Sec. 570.202  Policy.

    Use simplified lease acquisition procedures to the maximum extent 
practicable for actions at or below the simplified lease acquisition 
threshold.



Sec. 570.203  Procedures.



Sec. 570.203-1  Market survey.

    Conduct a market survey to identify potential sources. Use 
information available in GSA or from other sources to identify locations 
that will meet the Government's requirements.



Sec. 570.203-2  Competition.

    (a) Solicit at least three sources to promote competition to the 
maximum extent practicable. If you have repeated requirements for space 
in the same market, and if practicable, invite two sources not included 
in the most recent solicitation to submit offers.
    (b) If you solicit only one source, document the file to explain the 
lack of competition.



Sec. 570.203-3  Soliciting offers.

    (a) Solicit offers by providing each prospective offeror a proposed 
short form lease or SFO. The short form lease or SFO must provide all 
the following information:
    (1) A description of the Government's requirements.
    (2) All award factors, including price or cost, and any significant 
subfactors you will consider in awarding the lease.
    (3) A statement of the relative importance of the evaluation factors 
and subfactors.
    (4) A statement of whether all evaluation factors other than cost or 
price, when combined, are either:
    (i) Significantly more important than cost or price.
    (ii) Approximately equal in importance to cost or price.
    (iii) Significantly less important than cost or price.
    (5) Either in full text or by reference, applicable FAR provisions 
and contract clauses required by 570.6.
    (b) As necessary, review with prospective offerors the Government's 
requirements, pricing matters, evaluation procedures and submissions of 
offers.



Sec. 570.203-4  Negotiations, evaluation, and award.

    (a) If you need to conduct negotiations, use the procedures in 
570.307.
    (b) Evaluate offers in accordance with the solicitation. Evaluate 
prices and document the lease file to demonstrate whether the proposed 
contract prices are fair and reasonable.
    (c) If the total price, including options, exceeds $500,000, 
consider whether you need cost and pricing data to determine that the 
price is fair and reasonable. In most cases the exceptions at FAR 
15.403-1 will apply.

[[Page 277]]

    (d) If the total contract value of the lease, including options, 
will exceed $500,000, the proposed awardee must provide an acceptable 
small business subcontracting plan. This requirement does not apply if 
the proposed awardee is a small business concern.
    (e) Make award to the responsible offeror whose proposal is most 
advantageous to the Government considering price and other factors 
included in the solicitation.

  Subpart 570.3_Contracting Procedures for Leasehold Interests in Real 
                                Property



Sec. 570.301  Market survey.

    Conduct a market survey to identify potential sources. Use 
information available in GSA or from other sources to identify locations 
capable of meeting the Government's requirements.



Sec. 570.302  Description of requirements.

    (a) The description of requirements depends on the nature of the 
space the agency needs and the market available to satisfy that need.
    (b) The description of requirements must include all the following:
    (1) A statement of the purpose of the lease.
    (2) Functional, performance, or physical requirements.
    (3) Any special requirements.
    (4) The delivery schedule.
    (c) The description must promote full and open competition. Include 
restrictive provisions or conditions only to the extent necessary to 
satisfy the agency's needs or as authorized by law.



Sec. 570.303  Solicitation for offers.



Sec. 570.303-1  Preparing the SFO.

    The SFO forms the basis for the lease negotiation process and 
becomes part of the lease. Document each SFO in writing or 
electronically. Include the information necessary to enable prospective 
offerors to prepare proposals. Each SFO, at a minimum, must provide all 
the following:
    (a) Describe the Government's requirements.
    (b) State the method the Government will use to measure space.
    (c) Explain how to structure offers.
    (d) Specify a date, time, and place for submission of offers.
    (e) Explain how the Government will evaluate offers.
    (f) Describe the source selection procedures the Government will 
use.
    (g) Include a statement outlining the information the Government may 
disclose in debriefings.
    (h) Include appropriate forms prescribed in 570.7.



Sec. 570.303-2  Issuing the SFO.

    Release the SFO to all prospective offerors at the same time.



Sec. 570.303-3  Late offers, modifications of offers, and withdrawals of 
          offers.

    Follow the procedures in FAR 15.208.



Sec. 570.303-4  Changes to SFOs.

    (a) If the Government's requirements change, either before or after 
receipt of proposals, issue an amendment. Document the amendment using 
the same method as for the SFO, written or electronic.
    (b) If time is critical, you may provide information on SFO 
amendments orally.
    (1) Make a record of the information provided.
    (2) Provide, or attempt to provide, the notice to all offerors or 
prospective offerors on the same day.
    (3) Promptly confirm the information provided orally in a written 
amendment.
    (c) Distribute an amendment as follows:
    (1) If before the proposal due date, send the amendment to all 
prospective offerors who were sent a copy of the SFO.
    (2) If after proposal receipt, send the amendment to each offeror 
who submitted a proposal.
    (d) If an amendment is so substantial that it requires a complete 
revision of the SFO, cancel the SFO and issue a new one.



Sec. 570.304  General source selection procedures.

    (a) These procedures apply to acquisitions of leasehold interests 
except if you use either:
    (1) Simplified lease acquisition procedures authorized by 570.2.

[[Page 278]]

    (2) Two-phase design-build selection procedures authorized by 
570.105-2.
    (b) The contracting officer is designated as the source selection 
official unless the HCA appoints another individual for a particular 
leasing action or group of leasing actions.
    (c) You must include price or cost to the Government and past 
performance as evaluation factors in every case.
    (d) The SFO must comply with FAR 15.304 and either:
    (1) FAR 15.101-1 if you will use the tradeoff process.
    (2) FAR 15.101-2 if you will use the lowest price technically 
acceptable source selection process.



Sec. 570.305  Two-phase design-build selection procedures.

    (a) These procedures apply to acquisitions of leasehold interests if 
you use the two-phase design-build selection procedures authorized by 
570.105-2.
    (b) The SFO must include all the following information:
    (1) The scope of work.
    (2) The evaluation factors and subfactors to be used in evaluating 
phase-one proposals and their relative importance.
    (3) The maximum number of offerors to be selected to submit 
competitive proposals in phase-two.
    (4) The evaluation factors, including cost or price, and subfactors 
to be used in evaluating phase-two proposals and selecting the 
successful offeror, and their relative importance.
    (c) The following procedures apply to phase-one evaluation factors:
    (1) Phase one factors include:
    (i) Specialized experience and technical competence.
    (ii) Capability to perform.
    (iii) Past performance of the offeror's team (including architect-
engineer and construction members of the team).
    (iv) Other appropriate factors, such as site or location.
    (2) Do not require offerors to submit detailed design information or 
cost or price information in phase one. Do not use cost related or price 
related evaluation factors.
    (d) Set the maximum number of offerors to be selected for phase-two 
to not exceed five (5) unless you determine that a number greater than 
five is both:
    (1) In the government's interest.
    (2) Consistent with the purpose and objectives of the two-phase 
selection process.
    (e) In phase-two, require detailed technical and price proposals. 
Evaluate the proposals using the procedures in 570.306.



Sec. 570.306  Evaluating offers.

    (a) You must evaluate offers solely in accordance with the factors 
and subfactors stated in the SFO.
    (b) Evaluate prices and document the lease file to demonstrate that 
the proposed contract price is fair and reasonable.
    (c) Evaluate past performance in accordance with FAR 15.305(a)(2).
    (d) Document the evaluation of award factors other than price listed 
in the solicitation. The file must include the basis for evaluation, an 
analysis of each offer, and a summary of findings.



Sec. 570.307  Negotiations.

    (a) Follow the procedures in FAR 15.306 and 15.307 for exchanges 
(including clarifications, communications, negotiations, discussions, 
and revisions).
    (b) Place a written record of all exchanges in the lease file.
    (c) Provide prompt written notice to any offeror excluded from the 
competitive range or otherwise eliminated from the competition in 
accordance with FAR 15.503(a).



Sec. 570.308  Award.

    (a) Make award to the responsible offeror whose proposal represents 
the best value after evaluation in accordance with the factors and 
subfactors in the SFO.
    (b) Make award in writing and in the timeframe specified in the SFO.
    (1) If you cannot make an award in that time, request in writing 
from each offeror an extension of the acceptance period through a 
specific date.
    (2) If time is critical, you may request the extensions orally. You 
must make a record of the requested and confirm it promptly in writing.
    (c) Notify unsuccessful offerors in writing or electronically in 
accordance with FAR 15.501 and 15.503(b).

[[Page 279]]

    (d) The source selection authority may reject all proposals received 
in response to an SFO, if doing so is in the best interest of the 
Government.



Sec. 570.309  Debriefings.

    The procedures of FAR 15.505 and 15.506 apply to leasing actions.

    Subpart 570.4_Special Aspects of Contracting for Continued Space 
                              Requirements



Sec. 570.401  Renewal options.

    (a) Exercise of options. Before exercising an option to renew, 
follow the procedures in 517.202 and 517.207. The contract must first 
provide the right to renew the lease.
    (b) Market survey. Before exercising an option to renew a lease, 
review current market information to ensure the rental rate in the 
option is fair and reasonable.



Sec. 570.402  Succeeding leases.



Sec. 570.402-1  General.

    (a) If a succeeding lease for the continued occupancy of space in a 
building does not exceed the simplified lease acquisition threshold, you 
may use the simplified procedures in 570.2. Explain the absence of 
competition in the contract file.
    (b) If a succeeding lease will exceed the simplified lease 
acquisition threshold, you may enter into the lease under either of the 
following conditions:
    (1) You do not identify any potential acceptable locations.
    (2) You identify potential acceptable locations, but a cost-benefit 
analysis indicates that award to an offeror other than the present 
lessor will result in substantial relocation costs or duplication of 
costs to the Government, and the Government cannot expect to recover 
such costs through competition.



Sec. 570.402-2  Publicizing/Advertising.

    Publish a notice if required by 505.101(c). The notice should:
    (a) Indicate the Government's lease is expiring.
    (b) Describe the requirement in terms of type and quantity of space.
    (c) Indicate the Government is interested in considering alternative 
space if economically advantageous.
    (d) Advise prospective offerors that the Government will consider 
the cost of moving, alterations, etc., when deciding whether it should 
relocate.
    (e) Provide a contact person for those interested in providing space 
to the Government.



Sec. 570.402-3  Market survey.

    Conduct a market survey following 570.301.



Sec. 570.402-4  No potential acceptable locations.

    If you do not identify any potential acceptable locations through 
the advertisement or the market survey, you may prepare a justification 
to negotiate directly with the present lessor. Fully document the 
efforts to locate alternative sources. Prepare the justification and 
obtain approval following FAR 6.3 and 506.3.



Sec. 570.402-5  Potential acceptable locations.

    If you identify potential acceptable locations through the 
advertisement or market survey, conduct a cost-benefit analysis 
following the procedures in 570.402-6. Based on the results of the cost-
benefit analysis, take appropriate action as follows:
    (a) If the cost-benefit analysis indicates that the Government will 
recover relocation costs and duplication of costs through competition, 
develop an SFO and negotiate with all interested parties following 
570.3.
    (b) If the cost-benefit analysis indicates that the Government 
cannot expect to recover relocation costs and duplication of costs 
through competition, prepare a justification for approval in accordance 
with FAR 6.3 and 506.3. Explain both:
    (1) How you performed the cost-benefit analysis.
    (2) That the cost-benefit analysis indicates that award to any other 
offeror will likely result in substantial costs to the Government that 
the Government cannot expect to recover through competition.

[[Page 280]]



Sec. 570.402-6  Cost-benefit analysis.

    (a) The cost-benefit analysis must consider all the following:
    (1) The prices of other potentially available properties.
    (2) Relocation costs, including estimated costs for moving, 
telecommunications, and alterations, amortized over the firm term of the 
lease.
    (3) Duplication of costs to the Government.
    (4) Other appropriate considerations.
    (b) Establish the prices for other potentially available properties 
by requesting each prospective offeror to provide an informational 
quotation for standard space for comparison purposes.
    (1) Adjust the prices quoted for standard space for any special 
requirements.
    (2) You do not need a formal SFO to obtain the informational 
quotation. However, you must provide a general description of the 
Government's needs.
    (3) If you obtain oral quotations, document the following 
information, as a minimum:
    (i) Name and address of the firm solicited.
    (ii) Name of the firm's representative providing the quote.
    (iii) Price(s) quoted.
    (iv) Description of the space and services for which the quote is 
provided.
    (v) Name of the Government employee soliciting the quotation.
    (vi) Date of the conversation.
    (4) Compare the informational quotations to the present lessor's 
price, adjusted to reflect the anticipated price for a succeeding lease.



Sec. 570.403  Expansion requests.

    (a) If the expansion space is in the general scope of the lease, you 
may acquire the space through a modification without further 
justification under FAR 6.3.
    (b) If the expansion space needed is outside the general scope of 
the lease, determine whether it is more prudent to provide the expansion 
space by supplemental agreement to the existing lease or to satisfy the 
requirement by competitive means.
    (1) Conduct a market survey to determine the availability of 
suitable alternative locations.
    (2) If you identify alternate locations that can satisfy the total 
requirement, perform a cost-benefit analysis to determine whether it is 
in the Government's best interest to relocate. Consider, as appropriate.
    (i) The cost of the alternate space compared to the cost of 
expanding at the existing location.
    (ii) The cost of moving.
    (iii) The cost of duplicating existing improvements.
    (iv) The cost of the unexpired portion of the firm lease term. If a 
termination is possible, use the actual cost of such an action.
    (v) the cost of disruption to the agency's operation.
    (c) If you determine not to use competitive procedures and the 
expansion space is outside the general scope of the lease:
    (1) If the estimated value of the acquisition does not exceed the 
simplified lease acquisition threshold, document the file as required by 
570.203-2(b).
    (2) If the estimated value of the acquisition exceeds the simplified 
lease acquisition threshold, prepare a justification for approval under 
FAR 6.3 and 506.3.



Sec. 570.404  Superseding leases.

    (a) Consider executing a superseding lease to replace an existing 
lease when the Government need numerous or detailed modifications to the 
space that would cause complications or substantially change the present 
lease.
    (b) If the value of the superseding lease exceeds the simplified 
lease acquisition threshold, the justification and approval requirements 
in FAR 6.3 and 506.3 apply. If the cost does not exceed the simplified 
lease acquisition threshold, you may use the simplified procedures in 
570.2 and explain the absence of competition in the file.



Sec. 570.405  Lease extensions.

    (a) This section applies to extension of the term of a lease to 
provide for continued occupancy on a short-term basis.
    (b) If the value of a lease extension will exceed the simplified 
lease acquisition threshold, the justification and approval requirements 
in FAR 6.3 and 506.3 apply. For extensions that will

[[Page 281]]

not exceed the simplified lease acquisition threshold, you may use the 
simplified procedures in 570.2 and explain the absence of competition in 
the file.
    (c) FAR 6.302-1 permits contracting without providing for full and 
open competition when the property or services needed by the agency are 
available from only one responsible source and no other type of property 
or services will satisfy the needs of the agency. This authority may 
apply to lease extensions in situations such as the following:
    (1) The agency occupying the leased space is scheduled to move into 
other Federally controlled space, but encounters unexpected delays in 
preparing the new space for occupancy.
    (2) The Government encounters unexpected delays outside of its 
control in acquiring replacement space.
    (3) The Government is consolidating various agencies occupying the 
leased space and you need to extend the terms of some leases to 
establish a common expiration date.

   Subpart 570.5_Special Aspects of Contracting for Lease Alterations



Sec. 570.501  General.

    (a) Acquire alterations through a modification to an existing lease 
if you meet all the following conditions:
    (1) The alterations fall in the general scope of the lease. Consider 
whether the work can be regarded as fairly and reasonably an inseparable 
part of the lease requirement originally contracted for.
    (2) The lessor is willing to perform the proposed alterations at a 
fair and reasonable price.
    (3) It is in the Government's interest to acquire the alterations 
from the lessor.
    (b) If proposed alterations are outside the general scope of the 
existing lease, decide whether to acquire the alterations through 
either:
    (1) A supplemental lease agreement, justified and approved under 
570.502-1.
    (2) Government performance or a separate contract. The lease must 
first provide the Government the right to perform alterations to the 
leased space.



Sec. 570.502  Alterations by the lessor.

    These procedures apply to alterations you acquire directly from a 
lessor by modification or supplement lease agreement.



Sec. 570.502-1  Justification and approval requirements.

    If the proposed alterations are outside the general scope of the 
lease and you plan to acquire them from the lessor without competition, 
the following justification and approval requirements apply:
    (a) If the alteration project will exceed the simplified lease 
acquisition threshold, the justification and approval requirements in 
FAR 6.3 and 506.3 apply.
    (b) If the alteration project will exceed $2,500, but not the 
simplified lease acquisition threshold, you may use simplified 
acquisition procedures and explain the absence of competition in the 
file.
    (c) If the alternation project will not exceed $2,500, no 
justification and approval is required.



Sec. 570.502-2  Procedures.

    (a) Scope of work. Prepare a scope of work for each alteration 
project.
    (b) Independent Government estimate. Obtain an independent 
Government estimate for each alteration project, including changes to 
existing alteration agreements with the lessor.
    (c) Request for proposal. (1) Provide the scope of work to the 
lessor, including any plans and specifications, and request a proposal. 
Indicate in the request for proposal if the Government will make 
progress payments and provide for retainage, when appropriate.
    (2) Request sufficient cost or price information to permit a price 
analysis.
    (d) Audits. If you require cost or pricing data and the alteration 
project will exceed $500,000, request an audit.
    (e) Proposal evaluation. (1) Determine if the proposal meets the 
Government's requirements.
    (2) Analyze price or cost. At a minimum, compare the proposed cost 
to the independent estimate and, if applicable, any audit received.
    (3) Analyze profit following FAR 15.404-4.

[[Page 282]]

    (4) Document your analysis under this paragraph and the resulting 
negotiation objectives.
    (f) Price negotiations. (1) Exercise sound judgment. You may make 
reasonable compromises as necessary.
    (2) The negotiated price should provide the lessor with the greatest 
incentive for efficient and economical performance.
    (3) Document negotiations in the contract file.
    (g) Award. Use GSA Form 276, Supplemental Lease Agreement. If the 
modification does not exceed the simplified acquisition threshold, you 
may use GSA Form 300, Order for Supplies or Services. Reference the 
lease on the form.
    (h) Inspection and payment. Do not make final payment for 
alterations until the work is:
    (1) Inspected by a qualified Government employee or independent 
Government contractor.
    (2) Confirmed as completed in a satisfactory manner.

[64 FR 37265, July 9, 1999; 64 FR 49844, Sept. 14, 1999]



Sec. 570.503  Alterations by the Government or through a separate 
          contract.

    (a) If the Government chooses to exercise its right to make the 
alterations rather than contracting directly with the lessor, the 
Government may either:
    (1) Have Federal employees perform the work.
    (2) Contract out the work using standard contracting procedures that 
apply to a construction contract performed on Federal property.
    (b) If the Government decides to contract for the work, invite the 
lessor, as well as all other prospective contractors, to submit an offer 
for the project.

       Subpart 570.6_Solicitation Provisions and Contract Clauses



Sec. 570.601  FAR provisions and clauses.

    Include provisions or clauses substantially the same as the 
following FAR provisions and clauses.

------------------------------------------------------------------------
             If . . .                        Then include . . .
------------------------------------------------------------------------
(a) the estimated value of the      52.204-3  Taxpayer Identification.
 acquisition exceeds $2,500.        52.219-1  Small Business Program
                                     Representations.
                                    52.222-36  Affirmative Action for
                                     Workers with Disabilities.
                                    52.232-23  Assignment of Claims.
                                    52.233-1  Disputes.
(b) the estimated value of the      52.222-21  Prohibition of Segregated
 acquisition exceeds $10,000.        Facilities.
                                    52.222-22  Previous Contracts and
                                     Compliance Reports.
                                    52.222-25  Affirmative Action
                                     Compliance.
                                    52.222-26  Equal Opportunity.
                                    52.222-35  Affirmative Action for
                                     Disabled Veterans and Veterans of
                                     the Vietnam Era.
                                    52.222-37  Employment Reports on
                                     Disabled Veterans and Veterans of
                                     the Vietnam Era.
(c) the estimated value of the      52.209-6  Protecting the
 acquisition exceeds $25,000.        Government's Interest when
                                     Subcontracting with Contractors
                                     Debarred, Suspended, or Proposed
                                     for Debarment.
(d) the estimated value of the      52.203-11  Certification and
 acquisition exceeds $100,000.       Disclosure Regarding Payments to
                                     Influence Certain Federal
                                     Transactions.
(e) the estimated value of the      52.203-2  Certificate of Independent
 acquisition exceeds the             Price Determination.
 simplified lease acquisition       52.203-7  Anti-Kickback Procedures.
 threshold.                         52.209-5  Certification Regarding
                                     Debarment, Suspension, Proposed
                                     Debarment, and Other Responsibility
                                     Matters.
                                    52.215-2  Audit and Records--
                                     Negotiation.
                                    52.219-8  Utilization of Small
                                     Business Concerns.
                                    52.223-6  Drug-Free Workplace.
                                    52.233-2  Service of Protest.
(f) the estimated value of the      52.219-9  Small Business
 acquisition exceeds $500,000.       Subcontracting Plan.
                                    52.219-16  Liquidated Damages--
                                     Subcontracting Plan.
(g) the estimated value of the      52.219-24  Small Disadvantaged
 acquisition exceeds $500,000 and    Business Participation Program--
 the acquisition includes an         Targets.
 evaluation factor that considers   52.219-25  Small Disadvantaged
 the extent of participation of      Business Participation Program--
 small disadvantaged business        Disadvantaged Status and Reporting.
 concerns in accordance with FAR
 19.12.
(h) the estimated value of the      52.222-24  Preaward On-Site Equal
 acquisition exceeds $10 million.    Opportunity Compliance Review.

[[Page 283]]

 
(i) you require cost or pricing     52.215-10  Price Reduction for
 data for work or services           Defective Cost or Pricing Data.
 exceeding $500,000.                52.215-12  Subcontractor Cost or
                                     Pricing Data.
(j) you authorize submission of     52.215-5  Facsimile Proposals.
 facsimile proposals.
(k) a negotiated acquisition        52.219-26  Small Disadvantaged
 provides monetary incentives        Business Participation Program--
 based on actual achievement of      Incentive Subcontracting.
 small disadvantaged business
 subcontracting targets under FAR
 19.1203 and 519.1203.
------------------------------------------------------------------------



Sec. 570.602  GSAR solicitation provisions.

    Each SFO must include provisions substantially the same as the 
following, unless you determine that the provision is not appropriate:


Sec. 552.270-1  Instructions to Offerors--Acquisition of Leasehold 
          Interests in Real Property. Use Alternate I if you decide that 
          it is advantageous to the Government to allow offers to be 
          submitted up to the exact time specified for award. Use 
          Alternate II if the Government intends to award without 
          discussions. These two alternates are not exclusive.

Sec. 552.270-2  Historic Preference.

Sec. 552.270-3  Parties to Execute Lease.



Sec. 570.603  GSAR contract clauses.

    Insert clauses substantially the same as the following in 
solicitations and contracts for leasehold interests in real property 
that exceed the simplified lease acquisition threshold, unless you 
determine that a clause is not appropriate. You do not require a 
deviation under 570.604 to determine that a clause in this section is 
not appropriate. Use the clauses at your discretion in actions at or 
below the simplified lease acquisition threshold.


Sec. 552.270-4  Definitions. You must use this clause if you use 
          570.270-28.

Sec. 552.270-5  Subletting and Assignment.

Sec. 552.270-6  Maintenance of Building and Premises--Right of Entry.

Sec. 552.270-7  Fire and Casualty Damage.

Sec. 552.270-8  Compliance with Applicable Law.

Sec. 552.270-9  Inspection--right of Entry.

Sec. 552.270-10  Failure in Performance.

Sec. 552.270-11  Successors Bound.

Sec. 552.270-12  Alterations.

Sec. 552.270-13  Proposals for Adjustment.

Sec. 552.270-14  Changes.

Sec. 552.270-15  Liquidated Damages. Insert this clause in solicitations 
          and contracts if you have a critical requirement to meet the 
          delivery date and you cannot establish an actual cost for the 
          loss to the Government resulting from late delivery.

Sec. 552.270-16  Adjustment for Vacant Premises.

Sec. 552.270-17  Delivery and Condition.

Sec. 552.270-18  Default in Delivery--Time Extensions.

Sec. 552.270-19  Progressive Occupancy.

Sec. 552.270-20  Payment.

Sec. 552.270-21  Effect of Acceptance and Occupancy.

Sec. 552.270-22  Default by Lessor During the Term.

Sec. 552.270-23  Subordination, Nondisturbance and Attornment

Sec. 552.270-24  Statement of Lease.

Sec. 552.270-25  Substitution of Tenant Agency.

Sec. 552.270-26  No Waiver.

Sec. 552.270-27  Integrated Agreement.

Sec. 552.270-28  Mutuality of Obligation.

Sec. 552.270-29  Acceptance of Space.



Sec. 570.604  Deviations to provisions and clauses.

    (a) You need a deviation approved under 501.4 to omit any required 
provision or clause.
    (b) You also need an approved deviation to modify the language of a 
provision or clause mandated by statute (e.g., GSAR 552.203-5, Covenant 
Against Contingent Fees, FAR 52.215-2, Audit and Records--Negotiation). 
The authorizing statue must allow for a waiver.
    (c) Certain clauses required by non-GSA regulations require approval 
of the issuing agency before you can delete or modify them. For example, 
52.222-26, Equal Opportunity; 52.222-35, Affirmative Action for Disabled 
Veterans and Veterans of the Vietnam Era; and 52.222-36, Affirmative 
Action for Workers with Disabilities, require the approval of the 
Department of Labor's Office of Federal Contract Compliance Programs 
before they can be deleted from or modified in the SFO or lease.

[[Page 284]]

                           Subpart 570.7_Forms



Sec. 570.701  Standard forms.

    Use Standard Form 2, U.S. Government Lease for Real Property, to 
award leases unless you use GSA Form 3626 (see 570.702). Delete the 
reference to the Standard Form 2-A in paragraph 7.



Sec. 570.702  GSA forms.

    (a) You may use GSA Form 3626, U.S. Government Lease for Real 
Property (Short Form), to award leases if you use the simplified leasing 
procedures in 570.2 or if you determine it advantageous to use.
    (b) You may use GSA Form 276, Supplemental Lease Agreement, for 
actions requiring the agreement of both parties. This includes actions 
such as amending an existing lease to acquire additional space, 
obtaining partial release of space, revising the terms of a lease, 
settling restoration claims, and acquiring alterations.
    (c) You may use GSA Form 1364, Proposal To Lease Space, to obtain 
offers from prospective offerors.

[[Page 285]]



                     CHAPTER 6--DEPARTMENT OF STATE




                           (Parts 600 to 699)

  --------------------------------------------------------------------

                          SUBCHAPTER A--GENERAL
Part                                                                Page
601             Department of State Acquisition Regulations 
                    System..................................         287
602             Definitions of words and terms..............         292
603             Improper business practices and personal 
                    conflicts of interest...................         292
604             Administrative matters......................         294
           SUBCHAPTER B--COMPETITION AND ACQUISITION PLANNING
605             Publicizing contract actions................         295
606             Competition requirements....................         296
607             Acquisition planning........................         298
609             Contractor qualifications...................         299
611             Describing agency needs.....................         302
          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
613             Simplified acquisition procedures...........         305
614             Sealed bidding..............................         305
615             Contracting by negotiation..................         306
616             Types of contracts..........................         307
617             Special contracting methods.................         307
                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
619             Small business programs.....................         309
622             Application of labor laws to Government 
                    acquisitions............................         314
623             Environment, conservation, occupational 
                    safety, and drug-free workplace.........         316
624             Protection of privacy and freedom of 
                    information.............................         317
625             Foreign acquisition.........................         318
626             Other socioeconomic programs................         319
             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
627             Patents, data, and copyrights...............         320

[[Page 286]]

628             Bonds and insurance.........................         320
629             Taxes.......................................         322
631             Contract cost principles and procedures.....         323
632             Contract financing..........................         323
633             Protests, disputes, and appeals.............         325
             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING
634             Major system acquisition....................         329
636             Construction and architect-engineer 
                    contracts...............................         329
637             Service contracting.........................         330
641             Acquisition of utility services.............         331
                    SUBCHAPTER G--CONTRACT MANAGEMENT
642             Contract administration and audit services..         332
643             Contract modifications......................         333
644             Subcontracting policies and procedures......         333
645             Government property.........................         333
647             Transportation..............................         334
648             Value engineering...........................         334
649             Termination of contracts....................         335
651             Use of Government sources by contractors....         335
                     SUBCHAPTER H--CLAUSES AND FORMS
652             Solicitation provisions and contract clauses         336
653             Forms.......................................         347

[[Page 287]]



                          SUBCHAPTER A_GENERAL

       PART 601_DEPARTMENT OF STATE ACQUISITION REGULATIONS SYSTEM

Sec.

Sec. 601.000  Scope of part.

               Subpart 601.1_Purpose, Authority, Issuance


Sec. 601.101  Purpose.

Sec. 601.105  Issuance.

Sec. 601.105-3  Copies.

Sec. 601.106  OMB approval under the Paperwork Reduction Act.

                      Subpart 601.2_Administration


Sec. 601.201  Maintenance of the FAR.

Sec. 601.201-1  The two councils.

              Subpart 601.3_Agency Acquisition Regulations


Sec. 601.301  Policy.

Sec. 601.302  Limitations.

Sec. 601.303  Publication and codification.

                  Subpart 601.4_Deviations from the FAR


Sec. 601.403  Individual deviations.

Sec. 601.404  Class deviations.

Sec. 601.405  Deviations pertaining to treaties and executive 
          agreements.

Sec. 601.470  Deviations from the DOSAR.

              Subpart 601.5_Agency and Public Participation


Sec. 601.570  Rulemaking.

      Subpart 601.6_Career Development, Contracting Authority, and 
                            Responsibilities


Sec. 601.601  General.

Sec. 601.602  Contracting officers.

Sec. 601.602-1  Authority.

Sec. 601.603  Selection, appointment, and termination of appointment.

Sec. 601.603-3  Appointment.

Sec. 601.603-70  Delegations of authority.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26159, July 11, 1988, unless otherwise noted.



Sec. 601.000  Scope of part.

    This part describes the Department of State Acquisition Regulation 
(DOSAR) in terms of establishment, relationship to the Federal 
Acquisition Regulation (FAR), arrangement, applicability, and deviation 
procedures.

[53 FR 26159, July 11, 1988, as amended at 59 FR 66750, Dec. 28, 1994]

               Subpart 601.1_Purpose, Authority, Issuance



Sec. 601.101  Purpose.

    The DOSAR is issued to provide Department guidance in accordance 
with the policy cited in FAR 1.301(a)(2). The portions of this 
regulation that affects the relationship between a Department of State 
organization and a contractor or potential contractor are published in 
this chapter 6 of title 48 of the Code of Federal Regulations, in 
accordance with FAR 1.301(b).

[59 FR 66750, Dec. 28, 1994]



Sec. 601.105  Issuance.



Sec. 601.105-3  Copies.

    The DOSAR is available on CD-ROM disks through the Department's 
INFOEXPRESS program, or through the Internet from A/OPE's Acquisition 
Website. The Internet address is: http://www.statebuy.gov/home.htm

[64 FR 43620, Aug. 11, 1999]



Sec. 601.106  OMB approval under the Paperwork Reduction Act.

    The Paperwork Reduction Act of 1980 (44 U.S.C. 3501-3520) requires 
that Federal agencies obtain approval from the Office of Management and 
Budget before collecting information from ten (10) or more members of 
the public. Individuals are not required to respond to information 
collection unless the OMB number and burden estimate information is 
provided. Accordingly, the information and recordkeeping requirements 
contained in this regulation have been approved by OMB under OMB Control 
Number 1405-0050. The burden estimate is 225,302 hours.

[64 FR 43620, Aug. 11, 1999]

[[Page 288]]

                      Subpart 601.2_Administration



Sec. 601.201  Maintenance of the FAR.



Sec. 601.201-1  The two councils.

    The Office of the Procurement Executive (A/OPE) represents the 
Department of State (DOS) on the Civilian Agency Acquisition Council. 
The Procurement Executive shall appoint a representative for this 
purpose. A/OPE is responsible for coordinating with all interested DOS 
elements proposed FAR revisions and for advocating FAR revisions sought 
by the Department.

[53 FR 26159, July 11, 1988, as amended at 59 FR 66750, Dec. 28, 1994]

              Subpart 601.3_Agency Acquisition Regulations



Sec. 601.301  Policy.

    (a) The Assistant Secretary of State for Administration is the 
agency head for the purposes of FAR 1.301 (see Delegation of Authority 
No. 120 (34 FR 18095, October 30, 1969), as amended by Delegation of 
Authority No. 120-4 (59 FR 38022, July 26, 1994)). Under Delegation of 
Authority No. 120-5 (59 FR 62771, December 6, 1994), the Assistant 
Secretary of State for Administration redelegated to the Procurement 
Executive the authority to prescribe, promulgate, and amend DOS 
acquisition policies, rules, and regulations.
    (b) The Department of State Acquisition Regulation (DOSAR) is 
prescribed under the authority of 22 U.S.C. 2658 and 40 U.S.C. 486(c).
    (c) The DOSAR implements and supplements the FAR.

[59 FR 66751, Dec. 28, 1994, as amended at 64 FR 43620, Aug. 11, 1999]



Sec. 601.302  Limitations.

    (a) The FAR and the DOSAR apply to all DOS acquisitions of personal 
property and services, including construction, both within and outside 
the United States, unless expressly excluded by this subpart, or exempt 
from the Federal Property and Administrative Services Act of 1949, as 
amended (40 U.S.C. 474(7)), or undertaken pursuant to section 208 of the 
State Department Basic Authorities Act of 1956, as amended (22 U.S.C. 
4308), or the Foreign Service Buildings Act of 1926, as amended (22 
U.S.C. 292 et seq.).
    (b) At posts where Joint Administrative Offices have been formed, 
the FAR and the DOSAR apply to all Agency for International Development 
(AID) administrative and technical support acquisitions, except in those 
areas which have been exempted by the cognizant administrative office.

[53 FR 26159, July 11, 1988, as amended at 59 FR 66751, Dec. 28, 1994; 
64 FR 43620, Aug. 11, 1999]



Sec. 601.303  Publication and codification.

    (a) The DOSAR is issued as Chapter 6 of Title 48, Code of Federal 
Regulations. The DOSAR is established as Chapter 6 of the Federal 
Acquisition Regulations System. The DOSAR is divided into the same 
parts, subparts, sections, subsections, and paragraphs as is the FAR. 
However, when the FAR coverage is adequate by itself there will be no 
corresponding DOSAR coverage. Where the DOSAR implements a specific 
part, subpart, section, or subsection of the FAR, the DOSAR coverage is 
numbered and titled to correspond to the appropriate FAR number and 
title, except that the DOSAR number will include a 6 or 60 such that 
there will always be three numbers to the left of the decimal. For 
example, the DOSAR implementation of FAR 14.1 is shown as 614.1 and the 
DOSAR implementation of FAR 1.301 is shown as 601.301. Materials that 
supplement the FAR are assigned the numbers 70 and up. For example, 
DOSAR requires additional definitions than those used in FAR; this 
supplementary material is provided in 602.101-70.
    (b) The DOSAR and its revisions are published in the Federal 
Register and in the Code of Federal Regulations, both of which may be 
purchased from the Superintendent of Documents, Government Printing 
Office, Washington, DC 20402.
    (c) The DOSAR shall be referenced in the same manner as described at 
FAR 1.105-2(c).

[53 FR 26159, July 11, 1988, as amended at 59 FR 66751, Dec. 28, 1994; 
64 FR 43620, Aug. 11, 1999]

[[Page 289]]

                  Subpart 601.4_Deviations from the FAR



Sec. 601.403  Individual deviations.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 1.403.

[53 FR 26159, July 11, 1988, as amended at 59 FR 66751, Dec. 28, 1994]



Sec. 601.404  Class deviations.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 1.404(a).

[53 FR 26159, July 11, 1988, as amended at 59 FR 66751, Dec. 28, 1994]



Sec. 601.405  Deviations pertaining to treaties and executive 
          agreements.

    The Procurement Executive shall determine whether a deviation 
pertaining to treaties and executive agreements is authorized under FAR 
1.405 or that a request for deviation is required under FAR 1.405(e).

[53 FR 26159, July 11, 1988, as amended at 59 FR 66751, Dec. 28, 1994]



Sec. 601.470  Deviations from the DOSAR

    The authority to approve any deviations from the DOSAR is reserved 
to the Procurement Executive.

[53 FR 26159, July 11, 1988, as amended at 59 FR 66751, Dec. 28, 1994]

              Subpart 601.5_Agency and Public Participation



Sec. 601.570  Rulemaking.

    (a) The DOSAR is promulgated and may be revised, as necessary, in 
accordance with FAR part 1.
    (b) The Procurement Executive shall issue all DOS acquisition 
regulations.

[59 FR 66751, Dec. 28, 1994]

      Subpart 601.6_Career Development, Contracting Authority, and 
                            Responsibilities



Sec. 601.601  General.

    The Procurement Executive is the agency head for the purposes of FAR 
1.601.



Sec. 601.602  Contracting officers.



Sec. 601.602-1  Authority.

    (a) DOS contracts are awarded pursuant to the foreign affairs 
management responsibilities conferred on the Secretary of State (22 
U.S.C. 2656), and the various laws, regulations, and Executive Orders 
relating thereto.
    (b) Except as otherwise provided by law, DOS regulations, and this 
DOSAR, the Procurement Executive has the authority to execute, award, 
and administer contracts, purchase orders, other contractual 
arrangements, and other agreements, including FAR-covered interagency 
acquisition agreements, for the expenditure of funds involved in the 
acquisition of real and personal property, services, and for the sale of 
personal property. The Procurement Executive may further delegate this 
authority to those DOS employees appointed or designated to the 
contracting activities enumerated in 601.603-70.
    (c) The contracting officer shall not award, modify, or terminate a 
contract unless all reviews, clearances, and approvals prescribed in the 
FAR or the DOSAR have been obtained, and all applicable requirements of 
law, the FAR, the DOSAR, and other regulations have been met.

[53 FR 26159, July 11, 1988, as amended at 55 FR 5774, Feb. 16, 1990; 59 
FR 66751, Dec. 28, 1994]



Sec. 601.603  Selection, appointment, and termination of appointment.



Sec. 601.603-3  Appointment.

    (a) General. There is no contracting officer authority conferred 
upon any DOS employee by virtue of position. The Procurement Executive 
appoints all DOS contracting officers, in conformance with FAR 1.603-3, 
with the one exception as noted in paragraph (b) of this section. The 
contracting officer shall retain the original copy of the Standard Form 
1402, Certificate of Appointment, signed by the Procurement Executive. 
Only qualified employees shall be appointed as contracting officers. A/
OPE is responsible for providing guidance and oversight in managing such 
appointments.

[[Page 290]]

    (b) Temporary warrants. The Chief of Mission is delegated the 
authority by the Procurement Executive to issue temporary contracting 
officer warrants for periods up to 90 calendar days in order to cover 
emergency, post-specific operational requirements (e.g., staffing gaps, 
medical evacuations, extended leave, etc.). These temporary appointments 
shall be executed on the Standard Form 1402, and a copy shall be 
furnished to A/OPE. The warrant shall contain both a dollar limitation 
of no more than $100,000 and a specific time period (not to exceed 90 
days) during which the warrant is effective.
    (c) Non-Federal employees. Only United States Government direct-hire 
employees who are U.S. citizens shall be appointed as contracting 
officers. Personal services contractors, Foreign Service Nationals, and 
Third Country Nationals are not eligible for appointment as DOS 
contracting officers.
    (d) Personal services agreements. Individuals who may sign personal 
services agreements (PSAs) are limited to the following:
    (1) An individual, or class of individuals, granted authority by the 
Director, PER/OE; or
    (2) Individuals with contracting officer certificates of 
appointment.

[59 FR 66752, Dec. 28, 1994, as amended at 64 FR 43620, Aug. 11, 1999]



Sec. 601.603-70  Delegations of authority.

    (a) Delegations. As stated in 601.603-3(a), there is no contracting 
officer authority conferred by virtue of position. Pursuant to 601.602-
1(b), the Procurement Executive has designated the following as 
contracting activities as defined in FAR 2.101. These authorities are 
not redelegable. In addition, specific individuals are designated as 
heads of contracting activities (HCAs) (see FAR 2.101):
    (1) Overseas posts. Each overseas post shall be regarded as a 
contracting activity to enter into and administer contracts for the 
expenditure of funds involved in the acquisition of supplies, equipment, 
publications, and services. The Principal Officer, the Administrative 
Officer, or the Supervisory General Services Officer are designated as 
HCAs; provided, that he/she has a contracting officer's warrant issued 
by the Procurement Executive. The Procurement Executive (or authorized 
A/OPE staff) may delegate to a contracting officer, on a case-by-case 
basis, the authority to award a contract or modification which exceeds 
the contracting officer's warrant level.
    (i) No authority is delegated to enter into cost-reimbursement, 
fixed-price incentive, or fixed-price redeterminable contracts.
    (ii) When expressly authorized by a U.S. Government agency which 
does not have a contracting officer at the post, the officers named in 
paragraph (a)(1) introductory text of this section may enter into 
contracts for that agency. Use of this authority is subject to the 
statutory authority of that agency and any special contract terms or 
other requirements necessary for compliance with any conditions or 
limitations applicable to the funds of that agency. The agency's 
authorization shall cite the statute(s) and state any special contract 
terms or other requirements with which the acquisition so authorized 
must comply. In view of the contracting officer's responsibility for the 
legal, technical, and administrative sufficiency of contracts, questions 
regarding the propriety of contracting actions that the post is required 
to take pursuant to this authority may be referred to the Department for 
resolution with the headquarters of the agency concerned.
    (2) Office of Foreign Buildings. The authority to enter into and 
administer contracts pursuant to the Foreign Service Buildings Act of 
1926, as amended (22 U.S.C. 292 et seq.), is delegated to the Deputy 
Assistant Secretary of State for Foreign Buildings.
    (3) Office of Logistics Management; Office of Acquisition Management 
(A/LM/AQM). The authority to enter into and administer contracts for the 
expenditure of funds involved in the acquisition of supplies and 
nonpersonal services is delegated to the Director or designee as the 
HCA.
    (4) Foreign Service Institute. The authority to enter into and 
administer contracts pursuant to Chapter 7, Title I, of the Foreign 
Service Act of 1980, as amended (22 U.S.C. 4021 et seq.), is delegated 
to the Director of the Foreign

[[Page 291]]

Service Institute, the Executive Director, the Deputy Executive 
Director, and the Supervisory Contracting Officer as the HCA.
    (5) Office of Foreign Missions. The authority to enter into and 
administer contracts pursuant to Title II of the State Department Basic 
Authorities Act of 1956, as amended (22 U.S.C. 4301 et seq.), is 
delegated to the Director, Office of Foreign Missions, and the 
Administrative Officer as the HCA.
    (6) U.S. Mission to the United Nations. The authority to enter into 
and administer contracts pursuant to the United Nations Participation 
Act of 1945, as amended (22 U.S.C. 287), is delegated to the Counselor 
for Administration as the HCA.
    (7) Moscow Embassy Building Control Office. The authority to enter 
into and administer contracts for the planning, design, construction and 
supplies for the embassy office building in Moscow is delegated to the 
Director, Moscow Embassy Building Control Office as the HCA.
    (8) Diplomatic Telecommunication Service--Program Office. The 
authority to enter into and administer contracts for the leasing or 
purchase of telecommunications services, circuits, subsystems, supplies 
and associated professional services is delegated to the Chief, 
Acquisition Branch as the HCA.
    (9) Regional Procurement Support Offices. The authority to enter 
into and administer contracts for the expenditure of funds involved in 
the acquisition of supplies, equipment, publications, and services on 
behalf of overseas posts is delegated to each Director, Regional 
Procurement Support Office (RPSO) as the HCA at the following locations:
    (i) RPSO Germany in conjunction with Embassy Bonn and Consulate 
General Frankfurt;
    (ii) RPSO Tokyo in conjunction with Embassy Tokyo;
    (iii) RPSO Singapore in conjunction with Embassy Singapore; and,
    (iv) RPSO Florida in conjunction with the Florida Regional Center.
    (b) Other delegations. Several DOS offices have been delegated 
limited procurement authority, although they have not been designated as 
HCAs. Matters requiring HCA resolution are referred to the A/LM/AQM. 
These delegations are provided only to warranted contracting officers in 
the respective offices. They are as follows:
    (1) Office of Language Services. The authority to enter into and 
administer simplified acquisition transactions under FAR Part 13 and 
orders against existing contracts up to the maximum ordering threshold 
or limitation for interpreting, translating, conference reporting, and 
related language support and escort services.
    (2) Office of Overseas Schools. The authority to enter into and 
administer simplified acquisition transactions under FAR Part 13 and 
orders against existing contracts up to the maximum ordering threshold 
or limitation pursuant to section 29 of the State Department Basic 
Authorities Act of 1956, as amended.
    (3) Library. The authority to enter into and administer simplified 
acquisition transactions under FAR Part 13 and orders against existing 
contracts up to the maximum ordering threshold or limitation pursuant to 
the provisions of the Public Printing and Documents Act of 1968, as 
amended, and for the acquisition of newspapers, books, maps, and 
periodicals.
    (4) Office of International Conferences. The authority to enter into 
and administer simplified acquisition transactions under FAR Part 13 and 
orders against existing contracts up to the maximum ordering threshold 
or limitation pursuant to section 5, Title I, of the Department of State 
Basic Authorities Act of 1956, as amended.
    (5) Bureau of Population, Refugees, and Migration. The authority to 
enter into and administer simplified acquisition transactions under FAR 
Part 13 and orders against existing contracts up to the maximum ordering 
threshold or limitation pursuant to the Migration and Refugee Assistance 
Act of 1962, as amended, and Executive Order 11077, dated January 22, 
1963.
    (6) Bureau of International Narcotics and Law Enforcement Affairs. 
The authority to enter into and administer simplified acquisition 
transactions under FAR Part 13, orders against existing contracts up to 
the maximum ordering threshold or limitation and personal services 
contracts pursuant to

[[Page 292]]

the Foreign Assistance Act of 1961, as amended; and, 48 CFR Chapter 7, 
Agency for International Development Acquisition Regulation, including 
any amendments thereto.
    (7) Office of Small and Disadvantaged Business Utilization. The 
authority to enter into and administer 8(a) purchase orders and 
contracts as a third party pursuant to the Memorandum of Understanding 
signed with the Small Business Administration.

[59 FR 66752, Dec. 28, 1994, as amended at 60 FR 39662, Aug. 3, 1995; 64 
FR 43620, Aug. 11, 1999]

                 PART 602_DEFINITIONS OF WORDS AND TERMS

                        Subpart 602.1_Definitions

Sec.

Sec. 602.101  Definitions.

Sec. 602.101-70  DOSAR definitions.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26162, July 11, 1988, unless otherwise noted.

                        Subpart 602.1_Definitions



Sec. 602.101  Definitions.



Sec. 602.101-70  DOSAR definitions.

    For the purposes of the DOSAR, unless otherwise indicated, the 
following terms have the meanings set forth in this subpart.
    Consolidated Receiving Point or CRP; means the contractor under 
contract to a Despatch Agency to receive and prepare items for shipment 
to a post. The CRP receives, records, consolidates, and packs items for 
shipment overseas under the direction of the Despatch Agency.
    Department or DOS means the Department of State, including all of 
its activities wherever located.
    Despatch Agency means the office responsible for the transportation 
of goods between the U.S. and posts within its specific geographic area 
as assigned by the Transportation Division, Office of Supply and 
Transportation. There are four Despatch Agencies, one each in New York 
City; Baltimore, Maryland; Miami, Florida; and, Seattle, Washington.
    Government means the Government of the United States of America 
unless specifically stated otherwise.
    Major system has the same definition as described in FAR 2.101; 
however, the Department of State's dollar threshold as defined in 
paragraph (b) is $30 million. The Under Secretary for Management is the 
head of the agency for the purposes of paragraph (c).
    Overseas post means a ``post'' located outside the United States of 
America.
    Post means a diplomatic or consular mission of the United States of 
America, administered or managed by the DOS.

[53 FR 26163, July 11, 1988, as amended at 59 FR 66753, Dec. 28, 1994; 
60 FR 39662, Aug. 3, 1995; 64 FR 43620, Aug. 11, 1999]

 PART 603_IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST

                        Subpart 603.1_Safeguards

Sec.

Sec. 603.104  Procurement integrity.

Sec. 603.104-5  Disclosure, protection, and marking of contractor bid or 
          proposal information and source selection information.

Sec. 603.104-10  Violations or possible violations.

       Subpart 603.2_Contractor Gratuities to Government Personnel


Sec. 603.204  Treatment of violations.

                      Subpart 603.4_Contingent Fees


Sec. 603.405  Misrepresentations or violations of the Covenant Against 
          Contingent Fees.

Subpart 603.6_Contracts with Government Employees or Organizations Owned 
                          or Controlled by Them


Sec. 603.601  Policy.

Sec. 603.602  Exceptions.

             Subpart 603.7_Voiding and Rescinding Contracts


Sec. 603.704  Policy.

Sec. 603.705  Procedures.

    Subpart 603.9_Whistleblower Protections for Contractor Employees


Sec. 603.905  Procedures for investigating complaints.

Sec. 603.906  Remedies.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

[[Page 293]]


    Source: 53 FR 26163, July 11, 1988, unless otherwise noted.

                        Subpart 603.1_Safeguards

    Source: 64 FR 43620, Aug. 11, 1999, unless otherwise noted.



Sec. 603.104  Procurement integrity.



Sec. 603.104-5  Disclosure, protection, and marking of contractor bid or 
          proposal information and source selection information.

    (a) The following classes of persons may be authorized to receive 
contractor bid or proposal information or source selection information 
by the contracting officer or head of the contracting activity, who is 
the agency head's designee, when such access is necessary to the conduct 
of an acquisition:
    (1) Individuals involved in the selection process, such as the 
Contracting Officer's Representative, technical evaluators, advisors, 
consultants, and the Source Selection Official;
    (2) Clerical personnel directly involved in the acquisition;
    (3) Supervisors in the contracting officer's chain of command;
    (4) Contracting personnel involved in reviewing or approving the 
solicitation, contract, or contract modification;
    (5) Individuals from offices who may be required to perform pre-
award audits, such as DCAA; and,
    (6) Personnel in the following offices: Office of Small and 
Disadvantaged Business Utilization (A/SDBU), Office of the Legal 
Adviser, Office of Legislative Affairs, Office of the Inspector General, 
Office of the Procurement Executive, the Small Business Administration, 
and the Office of Federal Contract Compliance Programs (Department of 
Labor).
    (c) All information which is considered proprietary or source 
selection information shall be marked to prevent its unauthorized 
disclosure before award. This may be performed by marking each page of 
proprietary or source selection material with the statement ``Source 
Selection Information--See FAR 3.104'' or ``Proprietary Information--See 
FAR 3.104'', as applicable. Alternatively, this requirement may be met 
by attaching Forms DS-1926, Proprietary Information (Cover Page), and 
DS-1927, Source Selection Information (Cover Page), to any proprietary 
and source selection information. Individuals responsible for preparing 
derivative documents which reference, cite, or paraphrase proprietary or 
source selection information, are responsible for marking such documents 
as indicated in this paragraph. The required marking or cover page shall 
be included when technical proposals are submitted for evaluation and 
when an audit is requested. After award, the procedures governing the 
Freedom of Information Act and related laws/regulations shall be 
followed regarding release of proprietary or source selection 
information.



Sec. 603.104-10  Violations or possible violations.

    (a)(1) The contracting officer shall report any violation or 
possible violation to the head of the contracting activity after he or 
she has reviewed the documentation and has concluded that there is no 
impact on the acquisition.
    (d)(2)(ii)(B) The Procurement Executive is the agency head's 
designee for the purposes of FAR 3.104-10(d)(2)(ii)(B).

       Subpart 603.2_Contractor Gratuities to Government Personnel



Sec. 603.204  Treatment of violations.

    (a) The Procurement Executive is the agency head's designee for the 
purposes of FAR 3.204.
    (b) Procedures. Upon a decision to proceed with an investigation of 
an alleged violation of the Gratuities clause, the Assistant Inspector 
General for Investigations shall provide to the contractor a written 
notice by certified mail, return receipt requested. The notice shall 
present the findings of the decision and shall establish a schedule, 
including location, for an investigative hearing for the purposes 
prescribed in FAR 3.204(b). As determined necessary by the Assistant 
Inspector General for Investigations, follow-up hearings may be 
scheduled. Upon completion of the investigation, the Assistant Inspector 
General for Investigations shall provide to the Procurement Executive a

[[Page 294]]

report and recommendation, together with all pertinent documentation.
    (c) In addition to the requirements of FAR 3.204(c), when the 
Procurement Executive determines that a violation has occurred, the 
Procurement Executive shall so notify the Assistant Inspector General 
for Investigations. The Assistant Inspector General for Investigations 
shall then notify the individual who made the report, the Office of the 
Legal Adviser, and, if appropriate, the Department of Justice.

                      Subpart 603.4_Contingent Fees



Sec. 603.405  Misrepresentations or violations of the Covenant Against 
          Contingent Fees.

    (a) The contracting officer may request the Office of the Inspector 
General to develop further information if the facts available are deemed 
insufficient to determine whether an actual violation has occurred. The 
contracting officer may also obtain the advice of the Office of the 
Legal Adviser as to the legality and general propriety of any 
information disclosed.

[64 FR 43621, Aug. 11, 1999]

Subpart 603.6_Contracts with Government Employees or Organizations Owned 
                          or Controlled by Them



Sec. 603.601  Policy.

    (a) It is Department policy not to award contracts to Federal 
employees, or businesses substantially owned or controlled by Federal 
employees.

[59 FR 66754, Dec. 28, 1994]



Sec. 603.602  Exceptions.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 3.602.

             Subpart 603.7_Voiding and Rescinding Contracts



Sec. 603.704  Policy.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 3.704.

[59 FR 66754, Dec. 28, 1994]



Sec. 603.705  Procedures.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 3.705.

[59 FR 66754, Dec. 28, 1994]

    Subpart 603.9_Whistleblower Protections for Contractor Employees

    Source: 64 FR 43621, Aug. 11, 1999, unless otherwise noted.



Sec. 603.905  Procedures for investigating complaints.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 3.905.



Sec. 603.906  Remedies.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 3.906.

                     PART 604_ADMINISTRATIVE MATTERS

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26163, July 11, 1988, unless otherwise noted.

            Subpart 604.5_Electronic Commerce in Contracting



Sec. 604.502  Policy.

    The Assistant Secretary of State for Administration is the agency 
head for the purposes of FAR 4.502.

[64 FR 43621, Aug. 11, 1999]

[[Page 295]]



            SUBCHAPTER B_COMPETITION AND ACQUISITION PLANNING

                  PART 605_PUBLICIZING CONTRACT ACTIONS

           Subpart 605.2_Synopsis of Proposed Contract Actions

Sec.

Sec. 605.202  Exceptions.

Sec. 605.202-70  Foreign acquisitions.

Sec. 605.207-70  Acquisitions available from only one responsible 
          source.

                Subpart 605.3_Synopses of Contract Awards


Sec. 605.303  Announcement of contract awards.

                  Subpart 605.4_Release of Information


Sec. 605.403  Requests from members of Congress.

Sec. 605.404  Release of long-range acquisition estimates.

Sec. 605.404-1  Release procedures.

                    Subpart 605.5_Paid Advertisements


Sec. 605.502  Authority.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26164, July 11, 1988, unless otherwise noted.

           Subpart 605.2_Synopsis of Proposed Contract Actions



Sec. 605.202  Exceptions.



Sec. 605.202-70  Foreign acquisitions.

    (a) Policy. In accordance with a Determination and Findings issued 
by the Assistant Secretary of State for Administration, the requirement 
for advance CBD notices for the Department's foreign acquisitions 
awarded by overseas contracting activities is waived. CBD notices may be 
published for any acquisition where the contracting officer decides that 
publication would be in the Department's best interests. This waiver 
shall remain in effect until May 19, 2001.
    (b) Procedures. Contracting officers at overseas contracting 
activities are not required to prepare an individual determination and 
findings to document their decision to waive the CBD notice 
requirements.
    (c) Competition requirements. Nothing in this section waives the 
requirement to obtain competition as required by FAR part 6 and DOSAR 
(48 CFR) part 606. Competition, including the use of written 
solicitation, shall be obtained in all cases to the extent feasible. If 
there are known U.S. firms or firms with U.S. affiliations in local 
residence capable of supplying the required supplies or services, the 
contracting activity shall ensure that those firms are included in the 
source list for the acquisition.
    (d) Policy exclusion. CBD waiver authority does not apply to local 
guard service contracts that exceed $250,000. Local guard service 
contracts that exceed $250,000 shall be synopsized in the CBD. Option 
year prices shall be included when computing the applicability of this 
threshold.

[60 FR 39662, Aug. 3, 1995, as amended at 64 FR 43621, Aug. 11, 1999]



Sec. 605.207-70  Acquisitions available from only one responsible 
          source.

    In addition to the information required at FAR 5.207, each synopsis 
of a proposed acquisition from only one responsible source shall include 
descriptions of the specific qualifications or capabilities required to 
perform the work and the information a potential source must submit.

                Subpart 605.3_Synopses of Contract Awards



Sec. 605.303  Announcement of contract awards.

    (a) Contracting officers shall make information available on awards 
over $10 million to the Office of Legislative Affairs, upon request, in 
sufficient time for an announcement by 5:00 p.m. Washington, DC time on 
the day of the award. This requirement applies only to awards made by 
domestic contracting activities where performance

[[Page 296]]

will take place within the United States or its possessions.

[59 FR 66755, Dec. 28, 1994, as amended at 64 FR 43621, Aug. 11, 1999]

                  Subpart 605.4_Release of Information



Sec. 605.403  Requests from members of Congress.

    (a) The Procurement Executive is the agency head for the purposes of 
FAR 5.403(a).

[59 FR 66755, Dec. 28, 1994]



Sec. 605.404  Release of long-range acquisition estimates.



Sec. 605.404-1  Release procedures.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 5.404-1(a) and the agency head for the purposes of FAR 
5.404-1(b).

[55 FR 5774, Feb. 16, 1990]

                    Subpart 605.5_Paid Advertisements



Sec. 605.502  Authority.

    (a) For paid advertisements in newspapers within the United States, 
the head of the contracting activity is the agency head's designee for 
the purposes of FAR 5.502(a). For acquisitions by overseas posts 
necessitating paid advertisements in newspapers outside the United 
States, the head of the contracting activity is the agency's head's 
designee for the purposes of FAR 5.502(a). When the head of the 
contracting activity is the contracting officer for the acquisition, no 
further approvals are necessary.

[59 FR 66755, Dec. 28, 1994]

                    PART 606_COMPETITION REQUIREMENTS

   Subpart 606.2_Full and Open Competition After Exclusion of Sources

Sec.

Sec. 606.202  Establishing or maintaining alternate sources.

           Subpart 606.3_Other Than Full and Open Competition


Sec. 606.302  Circumstances permitting other than full and open 
          competition.

Sec. 606.302-1  Only one responsible source and no other supplies or 
          services will satisfy agency requirements.

Sec. 606.302-4  International agreement.

Sec. 606.302-6  National security.

Sec. 606.302-7  Public interest.

Sec. 606.303-1  Requirements.

Sec. 606.304  Approval of the justification.

Sec. 606.304-70  Acquisitions by overseas posts.

Sec. 606.370  Department of State standardization program.

                   Subpart 606.5_Competition Advocates


Sec. 606.501  Requirement.

Sec. 606.501-70  Overseas posts.

Sec. 606.570  Solicitation provision.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26165, July 11, 1988, unless otherwise noted.

   Subpart 606.2_Full and Open Competition After Exclusion of Sources



Sec. 606.202  Establishing or maintaining alternate sources.

    The Procurement Executive is the agency head for the purposes of FAR 
6.202.

           Subpart 606.3_Other Than Full and Open Competition



Sec. 606.302  Circumstances permitting other than full and open 
          competition.



Sec. 606.302-1  Only one responsible source and no other supplies or 
          services will satisfy agency requirements.

    (b)(4) The Procurement Executive is the agency head for the purposes 
of FAR 6.302-1(b)(4).

[59 FR 66755, Dec. 28, 1994]



Sec. 606.302-4  International agreement.

    (b)(2) In accordance with FAR 6.302-4, guard services shall be 
acquired from the host government only when it is the sole available 
source.

[59 FR 66755, Dec. 28, 1994]

[[Page 297]]



Sec. 606.302-6  National security.

    (b) This subsection applies to all acquisitions involving national 
security information, regardless of dollar amount. In no case shall 
information be classified in order to restrict competition. Information 
may be classified only when its authorized disclosure could be expected 
to cause damage to national security.
    (c) (1) The Chief, Controls Division, Office of Intelligence 
Liaison, Directorate for Coordination, Bureau of Intelligence and 
Research, is responsible for reviewing and certifying on any proposed 
acquisitions derived from or funded or administered by intelligence 
community agencies that involve sensitive compartmented information and 
ensuring that the provisions of Executive Order 12958 and FAR 6.302-6 
have been met. The Chief, Information Security Programs Division, Office 
of Information Security Technology, Bureau of Diplomatic Security, is 
responsible for reviewing and certifying on all other proposed 
acquisitions funded by the Department of State that involve national 
security information and ensuring that the provisions of Executive Order 
12958 and FAR 6.302-6 have been met. When disclosure of the Department's 
needs through full and open competition would compromise national 
security, the Justification for Other than Full and Open Competition 
shall include the following specific information:
    (i) How national security would be compromised if the Department of 
State's (or other agencies') needs were disclosed in the Commerce 
Business Daily;
    (ii) Why the CBD synopsis cannot be worded in such a manner that 
national security would not be compromised;
    (iii) Necessity for access to classified information to prepare 
technical and/or cost proposal and level of security clearance required;
    (iv) Necessity for access to classified information to perform the 
proposed contract and level of security clearance required;
    (v) Number and value of contracts that the justification covers; and
    (vi) A statement as follows: ``I hereby certify that the national 
security concerns of the referenced acquisition(s) meet the criteria set 
forth in Executive Order 12958 and FAR 6.302-6''.
    (2) Any acquisition involving national security information shall be 
publicized in the Commerce Business Daily unless disclosure of the 
agency's needs would compromise national security.
    (3) The contracting officer is responsible for soliciting offers 
from as many potential sources as is practicable under the 
circumstances. However, given the sensitivity required for acquisitions 
involving national security information, it is expected that 
requirements offices will work closely with the contracting officer in 
maximizing competition.

[59 FR 66755, Dec. 28, 1994, as amended at 64 FR 43621, Aug. 11, 1999]



Sec. 606.302-7  Public interest.

    The authority to approve the determination prescribed in FAR 6.302-
7(c) is reserved to the Secretary of State.



Sec. 606.303-1  Requirements.

    Justifications for contract actions prescribed in FAR 6.303-1(d) 
shall be forwarded by the contracting officer to A/OPE for transmittal 
to the Office of the United States Trade Representative.

[53 FR 26165, July 11, 1988, as amended at 59 FR 66755, Dec. 28, 1994]



Sec. 606.304  Approval of the justification.

    (a) (2) The approval authority for a proposed contract over $500,000 
but not exceeding $10,000,000 for domestic contracting activities that 
do not have a competition advocate is the Department Competition 
Advocate.
    (d) The estimated dollar value of all options shall be included in 
determining the approval level of a justification.

[59 FR 66755, Dec. 28, 1994, as amended at 64 FR 43621, Aug. 11, 1999]



Sec. 606.304-70  Acquisitions by overseas posts.

    The Departmental Competition Advocate is the approval authority for 
the purposes of FAR 6.304(a)(3). This authority is not redelegable. Any 
such justification must be transmitted

[[Page 298]]

through the Principal Officer at the overseas post.

[59 FR 66756, Dec. 28, 1994]



Sec. 606.370  Department of State standardization program.

    (a) It is the Department's policy to promote full and open 
competition in all procurement actions. The authority at 41 U.S.C. 
253(c)(1) shall be used with respect to standardization when only 
specified makes and models of equipment will satisfy the Department's 
needs and only one source is available. This policy applies to all 
acquisitions involving standardization, regardless of dollar amount.
    (b) Contracts awarded under the authority at 41 U.S.C. 253(c)(1) 
shall be supported by the written justification described in FAR 6.303. 
The contracting officer, requirements office, procuring activity 
competition advocate, and the Procurement Executive shall approve all 
Justifications for Other than Full and Open Competition that cite 
standardization of technical equipment as justification to restrict 
competition. The Administrative Officer at each post is the procuring 
activity competition advocate for that post and the requirements office 
at post is the embassy functional office responsible for identifying the 
need to contract.
    (c) Procurement of specified makes and models of technical equipment 
and systems, for which there is only one source of supply, is considered 
other than full and open competition. Such procurements shall be 
supported by an approved Justification for Other than Full and Open 
Competition. The justification shall include the content requirements of 
FAR 6.303-2. The justification shall also address potential cost savings 
in areas such as inventory, operations, training, maintenance, repairs, 
and administrative and management support. Areas of consideration for 
potential cost savings shall be supported by detailed estimates as 
attachments to the justification. Justifications shall specify an 
effective period, which shall bear a reasonable relationship to the life 
of the technical equipment. The effective period shall not exceed six 
years with a review at the end of the first three years. Periodic 
reviews shall be made during the standardization period to determine 
whether the standardization should be continued, revised or canceled.

[59 FR 66756, Dec. 28, 1994]

                   Subpart 606.5_Competition Advocates



Sec. 606.501  Requirement.

    (a) The Procurement Executive is the head of the agency for the 
purposes of FAR 6.501 and designates the Department Competition 
Advocate.
    (b) A contracting activity competition advocate has been designated 
for A/LM/AQM. The Department Competition Advocate is the activity 
competition advocate for all other domestic contracting activities.

[59 FR 66756, Dec. 28, 1994, as amended at 64 FR 43622, Aug. 11, 1999]



Sec. 606.501-70  Overseas posts.

    The Administrative Officer at each overseas post is the competition 
advocate for that post.



Sec. 606.570  Solicitation provision.

    The contracting officer shall insert the provision at 652.206-70, 
Competition Advocate/Ombudsman, in all solicitations exceeding the 
simplified acquisition threshold.

[64 FR 43622, Aug. 11, 1999]

                      PART 607_ACQUISITION PLANNING

    Authority: 22 U.S.C. 2658; 40 U.S.C. 486(c); 48 CFR subpart 1.3.

                     Subpart 607.1_Acquisition Plans



Sec. 607.103  Agency-head responsibilities.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 7.103.

[55 FR 5774, Feb. 16, 1990]

[[Page 299]]

                   PART 609_CONTRACTOR QUALIFICATIONS

                Subpart 609.2_Qualifications Requirements

Sec.

Sec. 609.202  Policy.

Sec. 609.206  Acquisitions subject to qualification requirements.

Sec. 609.206-1  General.

         Subpart 609.4_Debarment, Suspension, and Ineligibility


Sec. 609.403  Definitions.

Sec. 609.403-70  DOSAR definitions.

Sec. 609.404  List of parties excluded from Federal procurement and 
          nonprocurement programs.

Sec. 609.405  Effect of listing.

Sec. 609.405-1  Continuation of current contracts.

Sec. 609.405-2  Restrictions on subcontracting.

Sec. 609.405-70  Termination action decision.

Sec. 609.406  Debarment.

Sec. 609.406-1  General.

Sec. 609.406-3  Procedures.

Sec. 609.407  Suspension.

Sec. 609.407-1  General.

Sec. 609.407-3  Procedures.

   Subpart 609.5_Organizational and Consultant Conflicts of Interests


Sec. 609.503  Waiver.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26165, July 11, 1988, unless otherwise noted.

                Subpart 609.2_Qualifications Requirements



Sec. 609.202  Policy.

    The authority prescribed in FAR 9.202(a)(1) is delegated, without 
power of redelegation, to the head of the contracting activity.

[53 FR 26165, July 11, 1988, as amended at 59 FR 66756, Dec. 28, 1994]



Sec. 609.206  Acquisitions subject to qualification requirements.



Sec. 609.206-1  General.

    (b) The authority prescribed in FAR 9.206-1(b) is delegated, without 
power of redelegation, to the head of the contracting activity.

[64 FR 43622, Aug. 11, 1999]

         Subpart 609.4_Debarment, Suspension, and Ineligibility



Sec. 609.403  Definitions.

    Debarring official means the Procurement Executive.
    Suspending official means the Procurement Executive.



Sec. 609.403-70  DOSAR definitions.

    Fact-finding official means the chairperson of a three member fact-
finding panel. The panel comprises one representative each from the 
Office of the Legal Adviser, the contracting activity, and the 
requirements office. The representative from the Office of the Legal 
Adviser is the panel chairperson.
    Notice means a written communication sent by certified mail (return 
receipt requested) to the last known address of the party, its 
identified counsel, or its agent. In the case of a business, such notice 
may be sent to any partner, principal officer, director, owner or co-
owner, or joint venturer. If no return receipt is received within 10 
calendar days of mailing, receipt shall then be presumed. This 
definition applies to the notice requirements in FAR 9.406-3 and FAR 
9.407-3.



Sec. 609.404  List of parties excluded from Federal procurement and 
          nonprocurement programs.

    A/OPE shall accomplish the agency responsibilities prescribed in FAR 
9.404(c)(1) through (c)(3). The authority to establish procedures 
prescribed in FAR 9.404(c)(5) is delegated, without power of 
redelegation, to the head of the contracting activity.

[53 FR 26165, July 11, 1988; 53 FR 36461, Sept. 20, 1988, as amended at 
55 FR 5774, Feb. 16, 1990; 59 FR 66756, Dec. 28, 1994]



Sec. 609.405  Effect of listing.

    (a) The Procurement Executive is the agency head's designee for the 
purposes of FAR 9.405(a).
    (d) In accordance with a FAR class deviation granted by the 
Procurement Executive, the following actions apply to actions awarded by 
DOS contracting activities:
    (1)(i) Contracting officers at overseas contracting activities may 
rely on the debarment certification submitted by

[[Page 300]]

bidders/offerors (FAR 52.209-5) as proof of eligibility for award when 
access to the current ``Lists of Parties Excluded from Procurement 
Programs'' is not reasonably available. For contracts which require A/
OPE review and approval, the contracting officer should request that A/
OPE perform the required review if the list is not available.
    (4)(i) For procurement actions (both domestic and overseas) that do 
not exceed the simplified acquisition threshold, contracting officers 
need not consult the ``List of Parties Excluded from Federal Procurement 
and Nonprocurement Programs'' prior to award. The list should be 
consulted whenever the contracting officer has reason to believe that a 
proposed contractor may appear on the list.
    (ii) Contracting officers at domestic contracting activities shall 
review the ``List of Parties Excluded from Federal Procurement and 
Nonprocurement Programs'', either in hard copy or electronic form, prior 
to awarding a procurement action exceeding the simplified acquisition 
threshold.

[59 FR 66756, Dec. 28, 1994, as amended at 60 FR 39662, Aug. 3, 1995; 64 
FR 43622, Aug. 11, 1999]



Sec. 609.405-1  Continuation of current contracts.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 9.405-1. The decision whether to terminate a current 
contract shall be made in consideration of the circumstances listed in 
609.405-70.



Sec. 609.405-2  Restrictions on subcontracting.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 9.405-2.



Sec. 609.405-70  Termination action decision.

    (a) Prior to making a decision to terminate, based on the 
consideration listed below, the contracting officer shall have the 
proposed action reviewed and approved by:
    (1) The Office of the Legal Adviser;
    (2) An individual one level above the contracting officer; and
    (3) For overseas posts, A/OPE.
    (b) Termination for default. Termination for default under a 
contract's default clause is appropriate when the circumstances giving 
rise to the debarment or suspension also constitute a default in the 
contractor's performance of that contract. Debarment or suspension of 
the contractor for reasons unrelated to the performance of that contract 
may not support a termination for default.
    (c) Termination for convenience or cancellation. Termination for 
convenience or cancellation under appropriate contract clauses should be 
considered when the contractor presents a significant risk to the 
Government in completing a current contract and when such termination 
for convenience or cancellation is determined to be in the Government's 
best interests. In making this determination, the contracting officer 
should consider such factors as the--
    (1) Seriousness of the cause for debarment or suspension;
    (2) Extent of contract performance;
    (3) Potential costs to the Government;
    (4) Urgency of the requirement and the impact of the delay; and/or
    (5) Availability of other safeguards to protect the Government's 
interests.

[53 FR 26165, July 11, 1988, as amended at 59 FR 66756, Dec. 28, 1994]



Sec. 609.406  Debarment.



Sec. 609.406-1  General.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 9.406-1(c).



Sec. 609.406-3  Procedures.

    (a) Investigation and referral. (1) DOS employees aware of any cause 
that may serve as the basis for debarment shall immediately refer those 
cases through the contracting officer to the debarring official. The 
debarring official shall immediately refer to the Office of the 
Inspector General all reported cases that involve possible criminal or 
fraudulent activities for investigation by that office. The Office of 
the Inspector General shall provide to the Procurement Executive a copy 
of its investigation report. The contracting officer shall provide to 
the

[[Page 301]]

Procurement Executive a copy of his or her intended actions in response 
to the Office of the Inspector General report.
    (2) Referrals for consideration of debarment shall include--
    (i) The cause for debarment (see FAR 9.406-2);
    (ii) A statement of facts;
    (iii) Copies of supporting documentary evidence and a list of all 
necessary or probable witnesses, including addresses and telephone 
numbers, together with a statement concerning their availability to 
appear at a fact-finding proceeding and the subject matter of their 
testimony;
    (iv) A list of all contractors involved, either as principals or as 
affiliates, including current or last known home and business addresses 
and ZIP codes;
    (v) A statement of the acquisition history with such contractors;
    (vi) A statement concerning any known pertinent active or potential 
criminal investigation, criminal or civil court proceedings, or 
administrative claim before Boards of Contract Appeals; and
    (vii) A statement from each DOS organizational element affected by 
the debarment action as to the impact of a debarment on DOS programs.
    (b) Decisionmaking process. (1) If the contractor does not respond 
to a debarment notice within 30 calendar days after receipt of the 
notice, the debarring official may put the debarment into effect.
    (2) In response to the debarment notice, if the contractor or its 
representative notifies the debarring official within 30 days after 
receipt of the notice that it wants to present information and arguments 
in person to the debarring official, that official shall chair such a 
meeting within 20 calendar days of receipt of the request, unless the 
contractor requests a longer period of time. The oral presentation shall 
be conducted informally and a transcript need not be made. However, the 
contractor may supplement its oral presentation with written information 
and arguments for inclusion in the administrative record.
    (3) Pursuant to FAR 9.406-3(b)(2), the contractor may request and 
shall be entitled to a hearing before the fact-finding panel. The fact-
finding panel shall conduct the hearing within 20 calendar days of 
receipt of the request, unless the contractor requests a longer period 
of time.
    (4) The debarring official shall convene the fact-finding panel for 
this purpose and shall provide the panel with a copy of all documentary 
evidence on the matter. Upon receipt of such material, the fact-finding 
official shall notify the contractor and schedule a hearing date.
    (5) In addition to the purposes provided in FAR 9.406-3(b)(2), the 
hearing is intended to provide the debarring official with findings of 
fact based on a preponderance of evidence submitted to the fact-finding 
panel and to provide the debarring official with a determination as to 
whether a cause for debarment exists, based on the facts as found.
    (6) The fact-finding panel shall conduct its hearing in accordance 
with rules promulgated by the fact-finding official. The rules shall be 
as informal as is practicable, consistent with FAR 9.406-3(b) The fact-
finding official is responsible for making the transcribed record of the 
hearing, unless the contractor and the fact-finding panel agree to waive 
the requirement for a transcript.
    (7) The fact-finding official shall deliver written findings and the 
transcribed record, if made, to the debarring official within 30 
calendar days after the hearing. The findings shall resolve any facts in 
dispute based on a preponderance of the evidence presented and recommend 
whether a cause for debarment exists.
    (c) Notice of proposal to debar. (1) Upon receipt of a complete 
referral and after consulting with the Office of the Legal Adviser, the 
debarring official shall decide whether to initiate debarment action.
    (2) When a determination is made to initiate action, the debarring 
official shall provide to the contractor and any specifically named 
affiliates written notice in accordance with FAR 9.406-3(c). A copy of 
the notice shall be provided to the DOS officer who made the referral 
and to each DOS organizational elements affected by the determination.

[[Page 302]]

    (3) When a determination is made not to initiate action, the 
debarring official shall so advise the DOS officer who made the 
referral.
    (d) Debarring official's decision. In addition to complying with FAR 
9.406-3(d) and FAR 9.406-3(e), the debarring official shall provide 
single copies of the decision to each DOS organizational element 
affected by the decision and to the General Services Administration in 
accordance with 609.404.

[53 FR 26165, July 11, 1988; 53 FR 36461, Sept. 20, 1988, as amended at 
64 FR 43622, Aug. 11, 1999]



Sec. 609.407  Suspension.



Sec. 609.407-1  General.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 9.407-1(d).



Sec. 609.407-3  Procedures.

    (a) Investigation and referral. Investigation and referral shall be 
accomplished as provided in 609.406-3(a), except that referrals made to 
the suspending official shall cite causes pertinent to a suspension 
action (see FAR 9.407-2).
    (b) Decisionmaking process. (1) If the contractor does not respond 
to a notice of suspension within 30 calendar days after receipt of the 
notice, the suspending official may proceed with completion of 
investigation.
    (2) The DOS decisionmaking process for a suspension action pursuant 
to FAR 9.407-3(b) follow those established for a debarment action (see 
609.406(b)), except that the contractor may request and shall be 
entitled to a hearing before the fact-finding panel only if permitted 
under FAR 9.407-3(b)(2).
    (c) Notice of suspension. Notice of suspension shall be accomplished 
as provided in 609.406-3(a), except that the suspending official shall 
process the notice in accordance with FAR 9.407-3(c).
    (d) Suspending official's decision. In addition to complying with 
FAR 9.407-3(d), the suspending official shall provide single copies of 
the decision to each DOS organizational element affected by the decision 
and to the General Services Administration in accordance with 609.404.

   Subpart 609.5_Organizational and Consultant Conflicts of Interests



Sec. 609.503  Waiver.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 9.503.

                    PART 611_DESCRIBING AGENCY NEEDS

Sec.

Sec. 611.002  Policy.

Sec. 611.002-70  Metric system implementation.

      Subpart 611.1_Selecting and Developing Requirements Documents


Sec. 611.103  Market acceptance.

                    Subpart 611.5_Liquidated Damages


Sec. 611.502  Policy.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 64 FR 43622, Aug. 11, 1999, unless otherwise noted.



Sec. 611.002  Policy.



Sec. 611.002-70  Metric system implementation.

    (a) Policy. The Metric Conversion Act of 1975, as amended by the 
Omnibus Trade and Competitiveness Act of 1988 (15 U.S.C. 205a, et seq.), 
requires Federal agencies to establish implementing guidelines pursuant 
to metric policy to adopt the metric system as the preferred system of 
weights and measurements for United States trade and commerce. This 
section establishes the Department of State's metric conversion 
guidelines.
    (b) Applicability. This section applies to all DOS acquisitions, 
except to the extent that such use is impractical or is likely to cause 
significant inefficiencies or loss of markets to U.S. firms.
    (c) Definitions.
    Dual system means the use of both traditional and metric systems. 
For example, an item is designated, produced and described in inch-pound 
values with soft metric values also shown for information or comparison.
    Hard metric means the use of only standard metric (SI) measurements 
in specifications, standards, supplies and services.

[[Page 303]]

    Hybrid system means the use of both traditional and hard metric 
values in specifications, standards, supplies and services.
    Measurement sensitive means any item having an application or 
meaning depending substantially on some measured quantity. For example, 
measurement sensitive items include product or performance criteria and 
standards binding on others, such as emission levels, size and weight 
limitations, etc.
    Metric system means the International System of Units (Le System 
International d'Unites (SI)) of the International Bureau of Weights and 
Measures.
    Metrication means any act that increases metric system use, 
including metric training and initiation or conversion of measurement 
sensitive processes and systems to the metric system.
    Soft metric means the result of mathematical conversion of inch-
pound measurements to metric equivalents. The physical dimensions, 
however, are not changed.
    Traditional system of weights and measurements means the predominant 
weight and measurement system currently used in the United States, also 
referred to as the ``inch-pound system.'' The traditional system 
includes such commonly used units as inch, foot, yard, mile, pint, 
quart, gallon, bushel, ounce (fluid and avoirdupois), pound, degree 
Fahrenheit, ampere, candela, and second.
    (d) Procedures. (1) DOS contracting activities shall implement the 
metric system in a manner consistent with 15 U.S.C. 205a, et seq.
    (2) All DOS contracting activities shall use the metric system in 
acquisition consistent with security, operations, economic, technical, 
logistical, training and safety requirements.
    (3) The Department shall encourage industry to adopt the metric 
system by acquiring commercially available metric products and services 
that meet the Department's needs whenever practical. Toward this end, 
solicitations for DOS acquisitions shall:
    (i) State all measurement sensitive requirements in metric terms 
whenever possible. Alternatives to hard metric are soft, dual and hybrid 
metric terms. The Metric Handbook for Federal Officials regarding the 
selection of proper metric units and symbols is available from the 
National Technical Information Service; and
    (ii) For contracts expected to exceed $500,000 contracting officers 
shall return to the requirements office all specifications and 
statements of work that are not expressed in some form of metric terms 
unless the requirements office has prepared a justification, for the 
approval of the contracting officer, for the use of non-metric 
specifications or statements of work. The justification shall be in a 
format as prescribed by the head of the contracting activity. Option 
year prices shall be considered when computing the $500,000 threshold.
    (4) Waivers are not required when ordering from Federal Supply 
Schedules.
    (5) Valid justifications for non-metric specifications or statements 
of work include, but are not limited to:
    (i) Existing specifications or standards are in inch-pound units, 
unless conversion of the existing specifications or standards is 
necessary or advantageous to the Government. Unnecessary retrofit of 
existing systems with new metric components should be avoided if the 
total cost of the retrofit, including redesign costs, exceeds $50,000;
    (ii) Metric is not the accepted industry system with respect to a 
business-related activity; however, soft, hybrid, or dual systems may be 
used during the transition to hard metric;
    (iii) The use of metric is impractical or is likely to cause 
significant inefficiencies or loss of markets to U.S. firms.
    (6) The contracting officer shall review and, if acceptable, approve 
the waiver prior to the release of the solicitation. The waiver shall be 
placed in the contract file. If the waiver is not approved, the 
contracting officer shall return it to the requirements office with an 
explanation for the disapproval.
    (7) The in-house operating metric costs shall be identified. 
Identification includes, but is not limited to, the cost of metric aids, 
tools, equipment, training and increased cost to develop metric 
specifications. All contracting activities and requirements offices 
shall

[[Page 304]]

maintain a record of any costs and/or savings brought about by metric 
conversion.
    (8) Bulk (loose, unpacked) materials shall be specified and 
purchased in metric or dual units.
    (9) Measuring devices, shop and laboratory equipment shall be 
purchased in metric or dual units.
    (10) Shipping allowances, bills of lading and other shipping 
documents shall be expressed in metric or dual units.

      Subpart 611.1_Selecting and Developing Requirements Documents



Sec. 611.103  Market acceptance.

    (a) The head of the contracting activity is the agency head for the 
purpose of FAR 11.103(a).

                    Subpart 611.5_Liquidated Damages



Sec. 611.502  Policy.

    (d) The head of the contracting activity is the agency head for the 
purpose of FAR 11.502(d).

[[Page 305]]



           SUBCHAPTER C_CONTRACTING METHODS AND CONTRACT TYPES

               PART 613_SIMPLIFIED ACQUISITION PROCEDURES

              Subpart 613.3_Simplified Acquisition Methods

Sec.

Sec. 613.303  Blanket purchase agreements (BPAs).

Sec. 613.303-5  Purchases under BPAs.

Sec. 613.305  Imprest funds and third party drafts.

Sec. 613.305-3  Conditions for use.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 64 FR 43623, Aug. 11, 1999, unless otherwise noted.

              Subpart 613.3_Simplified Acquisition Methods



Sec. 613.303  Blanket purchase agreements (BPAs).



Sec. 613.303-5  Purchases under BPAs.

    (c) In accordance with FAR 13.303-5(c), BPAs shall be awarded to 
small businesses to the maximum extent practicable.



Sec. 613.305  Imprest funds and third party drafts.



Sec. 613.305-3  Conditions for use.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 13.305-3(a).

                         PART 614_SEALED BIDDING

                   Subpart 614.2_Solicitation of Bids

Sec.

Sec. 614.201  Preparation of Invitation for Bids (IFB).

Sec. 614.201-70  Use of English language.

           Subpart 614.4_Opening of Bids and Award of Contract


Sec. 614.402  Opening of bids.

Sec. 614.402-1  Unclassified bids.

Sec. 614.402-70  Waiver of public opening of bids.

Sec. 614.404  Rejection of bids.

Sec. 614.404-1  Cancellation of invitations after opening.

Sec. 614.407  Mistakes in bids.

Sec. 614.407-3  Other mistakes disclosed before award.

Sec. 614.407-4  Mistakes after award.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26168, July 11, 1988, unless otherwise noted.

                   Subpart 614.2_Solicitation of Bids

    Source: 64 FR 43623, Aug. 11, 1999, unless otherwise noted.



Sec. 614.201  Preparation of Invitation for Bids (IFB).



Sec. 614.201-70  Use of English language.

    Use of English language solicitations and contracts is mandatory 
unless a deviation has been approved by the Procurement Executive in 
accordance with 601.470. If any part of a contract is not written in the 
English language, the contracting officer shall attach an accurate 
English language translation of such part to the original and each copy 
of the contract, unless the contracting officer determines such action 
is infeasible.

           Subpart 614.4_Opening of Bids and Award of Contract



Sec. 614.402  Opening of bids.



Sec. 614.402-1  Unclassified bids.

    After the unclassified bids have been opened pursuant to FAR 14.402-
1, the bid opening officer shall announce that the opening of bids has 
been completed and that all bidders will be notified as soon as possible 
regarding the award.



Sec. 614.402-70  Waiver of public opening of bids.

    Overseas posts may request waiver of the public opening of bids if 
that activity is inconsistent with local law or legal practice, or with 
post security. For that purpose, the Procurement Executive must approve 
a deviation in accordance with 601.470.

[[Page 306]]



Sec. 614.404  Rejection of bids.



Sec. 614.404-1  Cancellation of invitations after opening.

    The authority to make the determination prescribed in FAR 14.404-
1(c) is delegated, without power of redelegation, to the head of the 
contracting activity. The head of the contracting activity shall obtain 
the concurrence of the Office of the Legal Adviser before making a 
determination pursuant to this subsection.
    (f) The head of the contracting activity is the agency head for the 
purpose of FAR 14.404-1(f). This authority is not redelegable.

[53 FR 26168, July 11, 1988, as amended at 59 FR 66758, Dec. 28, 1994; 
64 FR 43623, Aug. 11, 1999]



Sec. 614.407  Mistakes in bids.



Sec. 614.407-3  Other mistakes disclosed before award.

    The authority to make the determinations prescribed in FAR 14.407 is 
delegated, without power of redelegation, to the head of the contracting 
activity. In conformance with FAR 14.407-3(f), the head of the 
contracting activity shall obtain the concurrence of the Office of the 
Legal Adviser before making any determinations pursuant to this 
subsection.

[53 FR 26168, July 11, 1988. Redesignated and amended at 64 FR 43623, 
Aug. 11, 1999]



Sec. 614.407-4  Mistakes after award.

    The authority to make all determinations prescribed in FAR 14.407-4 
is delegated, without power of redelegation, to the head of the 
contracting activity. In conformance with FAR 14.407-4(d), the head of 
the contracting activity shall consult with the Office of the Legal 
Adviser before making any determinations pursuant to this subsection.

[53 FR 26168, July 11, 1988. Redesignated and amended at 64 FR 43623, 
Aug. 11, 1999]

                   PART 615_CONTRACTING BY NEGOTIATION

   Subpart 615.2_Solicitation and Receipt of Proposals and Information

Sec.

Sec. 615.204  Contract format.

Sec. 615.205  Issuing solicitations.

Sec. 615.205-70  Use of English language.

                     Subpart 615.3_Source Selection


Sec. 615.303  Responsibilities.

                   Subpart 615.6_Unsolicited Proposals


Sec. 615.604  Agency points of contact.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 64 FR 43623, Aug. 11, 1999, unless otherwise noted.

   Subpart 615.2_Solicitation and Receipt of Proposals and Information



Sec. 615.204  Contract format.

    (e) The Procurement Executive is the agency head's designee for the 
purposes of FAR 15.204(e).



Sec. 615.205  Issuing solicitations.

    (a) Contracting officers shall release copies of solicitation 
mailing lists in accordance with FAR 14.205-5(a). However, the list of 
those firms which actually submit proposals is not releasable. Requests 
for information other than solicitation mailing lists shall be handled 
under the Freedom of Information Act.



Sec. 615.205-70  Use of English language.

    The requirements of DOSAR 614.201-70 also apply when contracting by 
negotiation.

                     Subpart 615.3_Source Selection



Sec. 615.303  Responsibilities.

    (a) The Procurement Executive is the agency head for the purposes of 
FAR 15.303(a).

[[Page 307]]

                   Subpart 615.6_Unsolicited Proposals



Sec. 615.604  Agency points of contact.

    (a)(4) The contact points for unsolicited proposals are the heads of 
the contracting activities.

                       PART 616_TYPES OF CONTRACTS

Sec.

Sec. 616.000  Scope of part.

                   Subpart 616.2_Fixed-Price Contracts


Sec. 616.203  Fixed-Price contracts with economic price adjustment.

Sec. 616.203-4  Contract clauses.

Sec. 616.207  Firm-fixed-price, level-of-effort term contracts.

Sec. 616.207-3  Limitations.

               Subpart 616.5_Indefinite-Delivery Contracts


Sec. 616.505  Ordering.

Sec. 616.506  Solicitation provisions and contract clauses.

Sec. 616.506-70  DOSAR contract clause.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26169, July 11, 1988, unless otherwise noted.



Sec. 616.000  Scope of part.

    The contracting officer may use any of the contract types described 
in FAR part 16 for acquisitions made under simplified acquisition 
procedures. The contracting officer shall document his/her decision to 
use a contract type in accordance with the requirements of FAR part 16.

[60 FR 39963, Aug. 3, 1995]

                   Subpart 616.2_Fixed-Price Contracts



Sec. 616.203  Fixed-Price contracts with economic price adjustment.



Sec. 616.203-4  Contract clauses.

    Contracting officers at domestic contracting activities may use an 
economic price adjustment clause based on cost indexes of labor or 
material in accordance with the circumstances listed in FAR 16.203-4(d) 
and after obtaining the approval of the head of the contracting 
activity. Overseas posts may use the clause at 652.216-71, Price 
Adjustment, when procuring continuing services (e.g., guard, janitorial, 
building maintenance, and gardening). Posts shall obtain A/OPE approval 
for any price adjustment clause that differs from the clause at 652.216-
71.

[53 FR 26169, July 11, 1988, as amended at 59 FR 66759, Dec. 28, 1994]



Sec. 616.207  Firm-fixed-price, level-of-effort term contracts.



Sec. 616.207-3  Limitations.

    The head of the contracting activity is the chief of the contracting 
office for the purposes of FAR 16.207-3.

               Subpart 616.5_Indefinite-Delivery Contracts



Sec. 616.505  Ordering.

    (b)(4) The Departmental Competition Advocate is designated the task 
and delivery order contract ombudsman.

[64 FR 43624, Aug. 11, 1999]



Sec. 616.506  Solicitation provisions and contract clauses.



Sec. 616.506-70  DOSAR contract clause.

    The contracting officer shall insert the clause at 652.216-70, 
Ordering--Indefinite-Delivery Contract, whenever the clause at FAR 
52.216-20, Definite Quantity, or the clause at FAR 52.216-21, 
Requirements, or the clause at FAR 52.216-22, Indefinite Quantity, is 
used.

[53 FR 26169, July 11, 1988. Redesignated at 64 FR 43624, Aug. 11, 1999]

                  PART 617_SPECIAL CONTRACTING METHODS

                   Subpart 617.1_Multiyear Contracting

Sec.

Sec. 617.104  General.

Sec. 617.105  Policy.

Sec. 617.105-1  Uses.

Sec. 617.108  Congressional notification.

                          Subpart 617.2_Options


Sec. 617.201  Definitions.

Sec. 617.201-70  DOSAR Definitions.

Sec. 617.204  Contracts.

[[Page 308]]

      Subpart 617.5_Interagency Acquisitions Under the Economy Act


Sec. 617.503  Determination and findings requirements.

Sec. 617.504-70  Ordering procedures.

            Subpart 617.6_Management and Operating Contracts


Sec. 617.602  Policy.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26169, July 11, 1988, unless otherwise noted.

                   Subpart 617.1_Multiyear Contracting

    Source: 64 FR 43624, Aug. 11, 1999, unless otherwise noted.



Sec. 617.104  General.

    (b) The Procurement Executive is the agency head for the purpose of 
FAR 17.104(b).



Sec. 617.105  Policy.



Sec. 617.105-1  Uses.

    (d) Every multiyear contract shall comply with FAR 17.104(c), unless 
an exception is approved through the budget process in coordination with 
the cognizant financial management office/comptroller.



Sec. 617.108  Congressional notification.

    (a) The Procurement Executive is the agency head for the purposes of 
FAR 17.108(a).

                          Subpart 617.2_Options



Sec. 617.201  Definitions.



Sec. 617.201-70  DOSAR Definitions.

    Evaluated option means an option that is evaluated for award 
purposes by adding the total price for the option(s) to the total price 
for the basic requirement.
    Price option means an option where the amount for the option is 
specified in or is reasonably determinable from the terms of the basic 
contract, as described in FAR 17.207(f) (1) through (5).
    Unevaluated option means an option that is not included in the 
evaluation for award purposes.
    Unpriced option means an option where the prices for the option 
quantities or performance periods are not specified in the contract at 
the time of award and the option prices are negotiated at the time the 
option is exercised.

[53 FR 26169, July 11, 1988, as amended at 59 FR 66759, Dec. 28, 1994]



Sec. 617.204  Contracts.

    (e) The Procurement Executive shall approve any solicitations or 
contracts which exceed the five (5) year maximum length for supplies or 
services.

[59 FR 66759, Dec. 28, 1994]

      Subpart 617.5_Interagency Acquisitions Under the Economy Act



Sec. 617.503  Determination and findings requirements.

    The authority to make the determination prescribed in FAR 17.503 is 
delegated to the head of the contracting activity.

[64 FR 43624, Aug. 11, 1999]



Sec. 617.504-70  Ordering procedures.

    (a) Department deputy assistant secretaries or their equivalents are 
authorized to execute Economy Act IAAs. Department contracting officers 
also are authorized to execute Economy Act IAAs, as prescribed in FAR 
17.504(a).
    (b) Department of State form DS-1921, Award/Modification of 
Interagency Acquisition Agreement (illustrated in part 653), shall be 
used for all Economy Act IAAs where the Department is the requesting 
agency. It shall also be used for Economy Act IAAs where the Department 
is the servicing agency if the requesting agency does not have a similar 
form that provides the same information.

[59 FR 66759, Dec. 28, 1994, as amended at 64 FR 43624, Aug. 11, 1999]

            Subpart 617.6_Management and Operating Contracts



Sec. 617.602  Policy.

    The Assistant Secretary for Administration is the agency head for 
the purposes of FAR 17.602.

[[Page 309]]



                   SUBCHAPTER D_SOCIOECONOMIC PROGRAMS

                    PART 619_SMALL BUSINESS PROGRAMS

                         Subpart 619.2_Policies

Sec.

Sec. 619.201  General policy.

    Subpart 619.4_Cooperation with the Small Business Administration


Sec. 619.402  Small Business Administration procurement center 
          representatives.

Sec. 619.402-70  DOS designee.

               Subpart 619.5_Set-Asides for Small Business


Sec. 619.501  General.

Sec. 619.505  Rejecting Small Business Administration recommendations.

Sec. 619.506  Withdrawing or modifying set asides.

     Subpart 619.6_Certificates of Competency and Determinations of 
                               Eligibility


Sec. 619.602  Procedures.

Sec. 619.602-1  Referral.

 Subpart 619.7_Subcontracting with Small Business, Small Disadvantaged 
            Business and Women-Owned Small Business Concerns


Sec. 619.705  Responsibilities of the contracting officer under the 
          subcontracting assistance program.

Sec. 619.705-1  General support of the program.

Sec. 619.705-3  Preparing the solicitation.

Sec. 619.705-4  Reviewing the subcontracting plan.

Sec. 619.705-6  Postaward responsibilities of the contracting officer.

Sec. 619.705-6-70  Reporting responsibilities.

Sec. 619.708-70  Solicitation provisions and contract clauses.

 Subpart 619.8_Contracting with the Small Business Administration (The 
                              8(a) Program)


Sec. 619.800  General.

Sec. 619.801  Definitions.

Sec. 619.803  Selecting acquisitions for the 8(a) program.

Sec. 619.803-70  Responsibilities of the Office of Small and 
          Disadvantaged Business Utilization (A/SDBU).

Sec. 619.803-71  Simplified procedures for 8(a) acquisitions under MOUs.

Sec. 619.804  Evaluation, offering, and acceptance.

Sec. 619.804-2  Agency offering.

Sec. 619.804-3  SBA acceptance.

Sec. 619.804-3-70  SBA acceptance under MOUs for acquisitions exceeding 
          $100,000.

Sec. 619.805  Competitive 8(a).

Sec. 619.805-2  Procedures.

Sec. 619.806  Pricing the 8(a) contract.

Sec. 619.808  Contract negotiation.

Sec. 619.808-1  Sole source.

Sec. 619.810  SBA appeals.

Sec. 619.811  Preparing the contracts.

Sec. 619.811-1  Sole source.

Sec. 619.811-2  Competitive.

Sec. 619.811-3  Contract clauses.

Sec. 619.812  Contract administration.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26170, July 11, 1988, unless otherwise noted.

                         Subpart 619.2_Policies



Sec. 619.201  General policy.

    (a) The Operations Director, Office of Small and Disadvantaged 
Business Utilization (A/SDBU), is responsible for performing all 
functions and duties prescribed in FAR 19.201 (c) and (d).
    (b) In addition to the requirements of FAR 19.201(b), each head of 
the contracting activity (see 601.603-70), or designee, is responsible 
for establishing in coordination with the A/SDBU Operations Director 
annual goals for the DOS small and disadvantaged business program.
    (c) The Assistant Secretary of State for Administration is the 
agency head for the purposes of FAR 19.201(c).
    (d) Pursuant to FAR 19.201(d), each Small and Disadvantaged Business 
Utilization Specialist (SDBUS) is responsible for--
    (1) Maintaining a program to locate capable small business, small 
disadvantaged business, and women-owned business sources to fulfill DOS 
acquisition requirements;
    (2) Coordinating inquiries and requests for advice from small 
business, small disadvantaged business, and women-owned business sources 
on DOS contracting and subcontracting opportunities and other 
acquisition matters;
    (3) Advising contracting activities on new or revised small 
business, small disadvantaged business, or women-owned business 
policies, regulations,

[[Page 310]]

procedures, and other related information;
    (4) Assuring that small business, small disadvantaged business and 
women-owned business concerns are provided adequate specifications or 
drawings by initiating actions, in writing, with appropriate technical 
and contracting personnel to ensure that all necessary specifications or 
drawings for current and future acquisitions, as appropriate, are 
available;
    (5) Reviewing all proposed acquisitions in excess of the simplified 
aquisition threshold, including commercial items using the simplified 
procedures of FAR subpart 13.5, to assure that small business, small 
disadvantaged business, and women-owned business sources will be 
afforded an equitable opportunity to compete and, as appropriate, 
initiating recommendations for small business or small disadvantaged 
business set-asides. This includes proposed contract modifications for 
new or additional requirements which do not fall within the original 
scope of the contract and which exceed the simplified acquisition 
threshold. This does not include the exercising of contract options;
    (6) Assuring that contract financing available under existing 
regulations is offered when appropriate and that requests by small 
business concerns for such financing are not treated as a handicap in 
the award of contracts;
    (7) Providing assistance to the contracting officer in making 
determinations concerning responsibility of prospective contractors 
whenever small business concerns are involved;
    (8) Participating in the evaluation of a prime contractor's small 
business and small disadvantaged business subcontracting plans;
    (9) Assuring that the participation of small business, small 
disadvantaged business, and women-owned business concerns is accurately 
reported;
    (10) Attending, as appropriate, debriefings to unsuccessful small 
business and small disadvantaged business concerns to assist those firms 
in understanding requirements for responsiveness and responsibility so 
that the firm may be able to qualify for future awards;
    (11) Making available to SBA copies of solicitations when so 
requested;
    (12) When a bid or offer from a small business, small disadvantaged 
business, or women-owned business has been rejected for 
nonresponsiveness or nonresponsibility, upon request, aid, counsel, and 
assist that firm in understanding requirements for responsiveness and 
responsibility so that the firm may be able to qualify for future 
awards;
    (13) Participating in Government-industry conferences to assist 
small business, small disadvantaged business and women-owned business 
concerns, including Business Opportunity/Federal Acquisition 
Conferences, Minority Business Enterprises Acquisition Seminars and 
Business Opportunity Committee meetings;
    (14) Maintaining a list of supplies and services that have been 
placed as repetitive small business set-asides;
    (15) Participating in the development, implementation, and review of 
automated source systems to assure that the interests of small business, 
small disadvantaged business, and women-owned business concerns are 
fully considered;
    (16) Advising potential sources how they can obtain information 
about competitive acquisitions;
    (17) Providing small business, small disadvantaged business, and 
women-owned business sources information regarding assistance available 
from Federal agencies such as the Small Business Administration, 
Minority Business Development Agency, Bureau of Indian Affairs, Economic 
Development Administration, National Science Foundation, Department of 
Labor and others, including State agencies and trade associations; and
    (18) Participating in interagency programs relating to small and 
small disadvantaged business matters as authorized by the A/SDBU 
Operations Director.

[53 FR 26170, July 11, 1988, as amended at 59 FR 66759, Dec. 28, 1994; 
60 FR 39663, Aug. 3, 1995; 64 FR 43624, Aug. 11, 1999]

[[Page 311]]

    Subpart 619.4_Cooperation with the Small Business Administration



Sec. 619.402  Small Business Administration procurement center 
          representatives.



Sec. 619.402-70  DOS designee.

    Where the FAR requires action by a Small Business Administration 
procurement center representative, but one has not been assigned to the 
DOS contracting activity, the A/SDBU Operations Director shall perform 
the action so required.

               Subpart 619.5_Set-Asides for Small Business



Sec. 619.501  General.

    (c) Contracting officers shall use Department of State Form DS-1910, 
Small Business Review--Actions Above the Simplified Acquisition 
Threshold, to document set-aside decisions.

[59 FR 66759, Dec. 28, 1994, as amended at 60 FR 39663, Aug. 3, 1995; 64 
FR 43624, Aug. 11, 1999]



Sec. 619.505  Rejecting Small Business Administration recommendations.

    The Procurement Executive is the agency head for the purposes of FAR 
19.505.



Sec. 619.506  Withdrawing or modifying set asides.

    (b) The Procurement Executive shall resolve disagreements between 
the A/SDBU Operations Director and the contracting officer.

[59 FR 66759, Dec. 28, 1994]

     Subpart 619.6_Certificates of Competency and Determinations of 
                               Eligibility



Sec. 619.602  Procedures.



Sec. 619.602-1  Referral.

    The contracting officer shall transmit to the A/SDBU Operations 
Director concurrently with the submission to the appropriate SBA 
Regional Office, a copy of the documentation supporting the 
determination that a small business concern is not responsible, as 
required by FAR 19.602-1(a).

 Subpart 619.7_Subcontracting with Small Business, Small Disadvantaged 
            Business and Women-Owned Small Business Concerns



Sec. 619.705  Responsibilities of the contracting officer under the 
          subcontracting assistance program.



Sec. 619.705-1  General support of the program.

    It is the Department's policy to incorporate its current fiscal year 
goals as negotiated with the SBA into all pertinent Department 
solicitations, in addition to the standard subcontract clauses. 
Incorporation of the goals does not require that large business prime 
contractors must subcontract, but does require that to the extent they 
plan to subcontract, specific goals be established for doing business 
with small, small disadvantaged, and women-owned firms. Where funds are 
available, an incentive clause such as that found in FAR 52.219-10, 
Incentive Subcontracting Program for Small and Small Disadvantaged 
Business Concerns, is encouraged.

[59 FR 66760, Dec. 28, 1994]



Sec. 619.705-3   Preparing the solicitation.

    To further promote the use of small, disadvantaged, and women-owned 
firms by large prime contractors, contracting officers are encouraged to 
consider the adequacy of the subcontracting plans, and/or past 
performance in achieving negotiated subcontract goals, as part of the 
overall evaluation of the technical proposals.

[64 FR 43624, Aug. 11, 1999]



Sec. 619.705-4  Reviewing the subcontracting plan.

    A/SDBU shall review subcontracting plans to determine if small and 
small disadvantaged businesses are afforded the maximum practicable 
opportunity to participate as subcontractors. A/SDBU shall recommend to 
the contracting officer changes needed to subcontracting plans found to 
be deficient.

[[Page 312]]



Sec. 619.705-6  Postaward responsibilities of the contracting officer.



Sec. 619.705-6-70  Reporting responsibilities.

    (a) The contracting officer shall forward to the A/SDBU Operations 
Director a copy of each subcontracting plan that was incorporated into a 
contract or contract modification. Each contracting activity shall 
maintain a list of its active prime contracts that contain 
subcontracting plans.
    (b) Contracting officers shall collect subcontracting data from 
contractors required to establish subcontracting plans in support of 
small and small disadvantaged business concerns. This data shall be 
collected annually and semiannually, using Standard Form 295, Summary 
Subcontracting Report, for the annual submissions, and Standard Form 
294, Subcontracting Report for Individual Contracts, for the semiannual 
submissions. The head of the contracting activity shall forward these 
reports to the A/SDBU Operations Director, not later than the 30th day 
of the month following the close of the reporting period.

[53 FR 26170, July 11, 1988, as amended at 59 FR 66760, Dec. 28, 1994]



Sec. 619.708-70  Solicitation provisions and contract clauses.

    The contracting officer shall insert a provision substantially the 
same as the provision at 652.219-70, Department of State Subcontracting 
Goals, in solicitations whenever the clause at FAR 52.219-9, Small 
Business and Small Disadvantaged Business Subcontracting Plan, is used.

[59 FR 66760, Dec. 28, 1994]

 Subpart 619.8_Contracting with the Small Business Administration (The 
                              8(a) Program)

    Source: 64 FR 43624, Aug. 11, 1999, unless otherwise noted.



Sec. 619.800  General.

    (d) Utilizing Memoranda of Understanding (MOUs), the SBA has 
delegated its authority to contract directly with program participants 
under Section 8(a) of the Small Business Act to the Senior Procurement 
Executives of various Federal contracting activities. The Department of 
State has signed an MOU with SBA, effective May 6, 1998. Under the MOU, 
a contract may be awarded directly to an 8(a) firm on either a sole 
source or competitive basis. The SBA reserves the right to withdraw any 
delegation issued as a result of an MOU; however, any such withdrawal 
shall have no effect on contracts currently awarded under the MOU.



Sec. 619.801  Definitions.

    National buy requirements includes all 8(a) contracts performed 
outside the United States and processed by the Small Business 
Administration.



Sec. 619.803  Selecting acquisitions for the 8(a) program.



Sec. 619.803-70  Responsibilities of the Office of Small and 
          Disadvantaged Business Utilization (A/SDBU).

    A/SDBU shall review the capabilities of 8(a) concerns and 
disseminate that information to DOS program and contracting personnel. 
As necessary, A/SDBU shall obtain from the SBA or 8(a) concerns 
supplemental information for DOS program and contracting personnel.



Sec. 619.803-71  Simplified procedures for 8(a) acquisitions under MOUs.

    Contracting activities may use the simplified acquisition procedures 
of FAR part 13 and DOSAR part 613 to issue purchase orders or contracts, 
not exceeding $100,000, to 8(a) participants. The $100,000 limitation 
for use of FAR part 13 simplified acquisition procedures applies to the 
acquisition of both commercial and non-commercial items. The following 
applies to such acquisitions:
    (a) Neither offering letters to, nor acceptance letters from, the 
SBA are required.
    (b) The contracting activity shall use the SBA's PRO-Net database on 
the Internet (http://www.sba.gov) to establish that the selected 8(a) 
firm is a current program participant.
    (c) Once an 8(a) contractor has been identified, the agency 
contracting officer shall establish the price with the selected 8(a) 
contractor.

[[Page 313]]

    (d) The contracting officer shall issue the purchase order or 
contract directly to the 8(a) firm in accordance with the provisions of 
FAR part 13 and DOSAR part 613. The contracting officer shall insert FAR 
clause 52.219-14, Limitations on Subcontracting, and DOSAR clause 
652.219-71, Section 8(a) Direct Award, in all purchase orders and 
contracts awarded under this subsection. The contracting officer's title 
shall include the contracting activity, as follows: Contracting Officer 
for the Department of State [insert contracting activity]. In addition, 
in accordance with the MOU, A/SDBU staff who have been issued limited 
contracting officer warrants for this purpose, shall sign the purchase 
order or contract as a third party.
    (e) The contracting officer shall forward to the SBA District Office 
serving the 8(a) firm a copy of the purchase order or contract within 
five days after the order is issued.



Sec. 619.804  Evaluation, offering, and acceptance.



Sec. 619.804-2  Agency offering.

    (a) When applicable, this notification shall identify that the 
offering is in accordance with the MOU identified in 619.800.



Sec. 619.804-3  SBA acceptance.



Sec. 619.804-3-70  SBA acceptance under MOUs for acquisitions exceeding 
          $100,000.

    (a) The SBA's decision whether to accept the requirement shall be 
transmitted to the contracting agency in writing within five working 
days of receipt of the offer.
    (b) The SBA may request, and the contracting agency may grant, an 
extension beyond the five-day limit.
    (c) SBA's acceptance letter should be faxed or e-mailed to the 
offering contracting agency.
    (d) If the offering contracting agency has not received an 
acceptance or rejection of the offering from SBA within five days of 
SBA's receipt of the offering letter, the contracting agency may assume 
that the requirement has been accepted and proceed with the acquisition.
    (e) The contents of the acceptance letter shall be limited to the 
eligibility of the recommended 8(a) contractor.



Sec. 619.805  Competitive 8(a).



Sec. 619.805-2  Procedures.

    (a) 8(a) acquisitions may also be conducted using simplified 
acquisition procedures (see FAR part 13). The award process is 
significantly streamlined where an MOU is in place.
    (c)(3) For requirements exceeding $100,000 processed under the MOU 
cited in 619.800, the contracting officer shall submit the name, 
address, and telephone number of the low offeror (in sealed bid 
acquisitions) or the apparent successful offeror (in negotiated 
acquisitions) to the SBA Business Opportunity Specialist at the field 
office servicing the identified 8(a) firm. The SBA shall determine the 
eligibility of the firm(s) and advise the contracting officer within two 
working days of the receipt of the request. If the firm is determined to 
be ineligible, the contracting officer shall submit information on the 
next low offeror or next apparent successful offeror, as applicable, to 
the cognizant SBA field office.



Sec. 619.806  Pricing the 8(a) contract.

    (a) When required by FAR subpart 15.4, the contracting officer shall 
obtain certified cost or pricing data directly from the 8(a) contractor 
if the contract is being awarded under the MOU cited in 619.800.



Sec. 619.808  Contract negotiation.



Sec. 619.808-1  Sole source.

    (a) If the acquisition is conducted under an MOU cited in 619.800, 
the 8(a) contractor is responsible for negotiating with the agency 
within the time established by the agency. If the 8(a) contractor does 
not negotiate within the established time and the agency cannot allow 
additional time, the agency may, after notification and approval by SBA, 
proceed with the acquisition from other sources.
    (b) If the acquisition is conducted under an MOU cited in 619.800, 
the agency is delegated the authority to negotiate directly with the 
8(a) participant; however, if requested by the 8(a)

[[Page 314]]

participant, the SBA may participate in the negotiations.



Sec. 619.810  SBA appeals.

    (d) The Procurement Executive is the agency head for the purposes of 
FAR 19.812(d).



Sec. 619.811  Preparing the contracts.



Sec. 619.811-1  Sole source.

    (d) If the award is to be made under an MOU cited in 619.800, the 
contract to be awarded by the contracting activity to the 8(a) firm 
shall be prepared in accordance with the contracting activity's normal 
procedures, given contract type and dollar amount, that the contracting 
activity would use for a similar, non-8(a) acquisition, except for the 
following:
    (1) The award form shall cite 41 U.S.C. 253(c)(5) or 10 U.S.C. 
2304(c)(5), as appropriate, and 15 U.S.C. 637(a) as the authority for 
use of other than full and open competition.
    (2) The contracting officer shall insert FAR 52.219-14, Limitations 
on Subcontracting, and DOSAR 652.219-71, Section 8(a) Direct Awards.
    (3) For acquisitions exceeding $100,000, the contracting activity 
shall include SBA's requirement number on the award document.
    (4) A single award document shall be used between the agency and the 
8(a) contractor, i.e., an SBA signature will not be required. The title 
of the agency contracting officer shall include the contracting 
activity, as follows: Contracting Officer for the Department of State 
[insert contracting activity]. In addition, in accordance with the MOU, 
A/SDBU staff who have been issued limited contracting officer warrants 
for this purpose shall sign the contract as a third party. The 8(a) 
contractor's signature shall be placed on the award document as the 
prime contractor. The 8(a) contractor's name and address shall be placed 
in the ``Awarded to'' or ``Contractor name'' block on the appropriate 
form.



Sec. 619.811-2  Competitive.

    (a) If the award is made under the delegation of 8(a) contracting 
authority, competitive contracts for 8(a) firms shall be prepared in 
accordance with the same standards as 8(a) sole source contracts. See 
619.811-1.
    (b) If the acquisition is conducted under the MOU cited in 619.800, 
the process for obtaining signatures shall be as specified in 619.811-
1(d)(4).



Sec. 619.811-3  Contract clauses.

    (d)(3) The contracting officer shall insert the clause at FAR 
52.219-18, Notification of Competition Limited to Eligible 8(a) 
Concerns, with its Alternate III (Deviation), in competitive 
solicitations and contracts exceeding $100,000 when the acquisition is 
processed under the MOU cited in 619.800.
    (f) The contracting officer shall insert the clause at FAR 52.219-
14, Limitations on Subcontracting, and DOSAR 652.219-71, Section 8(a) 
Direct Awards, in all solicitations and contracts that are processed 
under the MOU cited at 619.800. The clauses at FAR 52.219-11, Special 
8(a) Contract Conditions; 52.219-12, Special 8(a) Subcontract 
Conditions; and, 52.219-17, Section 8(a) Award, shall not be used.



Sec. 619.812  Contract administration.

    (d) The head of the contracting activity is the agency head for the 
purposes of FAR 19.812(d). Awards under the MOU cited in 619.800 are 
subject to 15 U.S.C. 637(a)(21). These contracts contain the clause at 
DOSAR 652.219-71, Section 8(a) Direct Awards, that requires the 8(a) 
contractor to notify the SBA and the contracting officer when ownership 
of the firm is being transferred.

      PART 622_APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITIONS

       Subpart 622.3_Contract Work Hours and Safety Standards Act

Sec.

Sec. 622.302  Liquidated damages and overtime pay.

   Subpart 622.4_Labor Standards for Contracts Involving Construction


Sec. 622.404  Davis-Bacon Act wage determinations.

Sec. 622.404-3  Procedures for requesting wage determinations.

[[Page 315]]


Sec. 622.404-6  Modifications of wage determinations.

Sec. 622.404-7  Correction of wage determinations containing clerical 
          errors.

Sec. 622.404-11  Wage determination appeals.

Sec. 622.406  Administration and enforcement.

Sec. 622.406-1  Policy.

Sec. 622.406-8  Investigations.

Sec. 622.406-9  Withholding from or suspension of contract payments.

Sec. 622.406-10  Disposition of disputes concerning construction 
          contract labor standards enforcement.

Sec. 622.406-11  Contract terminations.

Sec. 622.406-12  Cooperation with the Department of Labor.

             Subpart 622.6_Walsh-Healey Public Contracts Act


Sec. 622.604  Exemptions.

Sec. 622.604-2  Regulatory exemptions.

               Subpart 622.8_Equal Employment Opportunity


Sec. 622.803  Responsibilities.

Sec. 622.807  Exemptions.

    Subpart 622.13_Disabled Veterans and Veterans of the Vietnam Era


Sec. 622.1303  Waivers.

Sec. 622.1308  Contract clauses.

         Subpart 622.14_Employment of Workers with Disabilities


Sec. 622.1403  Waivers.

Sec. 622.1408  Contract clause.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26172, July 11, 1988, unless otherwise noted.

       Subpart 622.3_Contract Work Hours and Safety Standards Act



Sec. 622.302  Liquidated damages and overtime pay.

    The authority to make the determination prescribed in FAR 22.302(c) 
is delegated, without power of redelegation, to the head of the 
contracting activity.

[55 FR 5774, Feb. 16, 1990]

   Subpart 622.4_Labor Standards for Contracts Involving Construction

    Source: 55 FR 5774, Feb. 16, 1990, unless otherwise noted.



Sec. 622.404  Davis-Bacon Act wage determinations.



Sec. 622.404-3  Procedures for requesting wage determinations.

    The cognizant contracting activity (see 601.603-70) is the 
contracting agency for the purposes of FAR 22.404-3(b) and (e)



Sec. 622.404-6  Modifications of wage determinations.

    The cognizant contracting activity is the contracting agency for the 
purposes of FAR 22.404-6.
    (b)(6) The head of the contracting activity is the agency head's 
designee for the purposes of FAR 22.404-6(b)(6).

[55 FR 5774, Feb. 16, 1990, as amended at 59 FR 66760, Dec. 28, 1994]



Sec. 622.404-7  Correction of wage determinations containing clerical 
          errors.

    The cognizant contracting activity is the contracting agency for the 
purposes of FAR 22.404-7.



Sec. 622.404-11  Wage determination appeals.

    The cognizant contracting activity is the contracting agency for the 
purposes of FAR 22.404-11.



Sec. 622.406  Administration and enforcement.



Sec. 622.406-1  Policy.

    The cognizant contracting activity is the contracting agency for the 
purposes of FAR 22.406-1(a).



Sec. 622.406-8  Investigations.

    (a) The chief of the contracting activity is responsible for 
conducting labor standards investigations as prescribed in FAR 22.406-
8(a).
    (d) The Procurement Executive is the agency head's designee for the 
purposes of FAR 22.406-8(d).



Sec. 622.406-9  Withholding from or suspension of contract payments.

    The authority to suspend contract payments pursuant to FAR 22.406-
9(b) is delegated, without power of redelegation, to the head of the 
contracting activity.

[[Page 316]]



Sec. 622.406-10  Disposition of disputes concerning construction 
          contract labor standards enforcement.

    The cognizant contracting activity is the contracting agency for the 
purposes of FAR 22.406-10(b).



Sec. 622.406-11  Contract terminations.

    The cognizant contracting activity is the contracting agency for the 
purposes of FAR 22.406-11.



Sec. 622.406-12  Cooperation with the Department of Labor.

    Any information furnished to the Department of Labor pursuant to FAR 
22.406-12(a) shall be submitted through the head of the contracting 
activity.

             Subpart 622.6_Walsh-Healey Public Contracts Act



Sec. 622.604  Exemptions



Sec. 622.604-2  Regulatory exemptions.

    The Procurement Executive is the agency head for the purposes of FAR 
22.604-2(c)(1).

               Subpart 622.8_Equal Employment Opportunity



Sec. 622.803  Responsibilities.

    (c) The Procurement Executive is the agency head for the purpose of 
FAR 22.803(c).

[64 FR 43626, Aug. 11, 1999]



Sec. 622.807  Exemptions.

    The Procurement Executive is the agency head for the purposes of FAR 
22.807(a)(1).

    Subpart 622.13_Disabled Veterans and Veterans of the Vietnam Era



Sec. 622.1303  Waivers.

    The Procurement Executive is the agency head for the purposes of FAR 
22.1303.



Sec. 622.1308  Contract clauses.

    The Procurement Executive is the agency head for the purposes of FAR 
22.1308 (a)(2) and (c).

[55 FR 5775, Feb. 16, 1990]

         Subpart 622.14_Employment of Workers with Disabilities



Sec. 622.1403  Waivers.

    The Procurement Executive is the agency head for the purposes of FAR 
22.1403.



Sec. 622.1408  Contract clause.

    The Procurement Executive is the agency head for the purposes of FAR 
22.1408.

[55 FR 5775, Feb. 16, 1990]

 PART 623_ENVIRONMENT, CONSERVATION, OCCUPATIONAL SAFETY, AND DRUG	FREE 
                                WORKPLACE

         Subpart 623.1_Pollution Control and Clean Air and Water

Sec.

Sec. 623.104  Exemptions.

Sec. 623.107  Compliance responsibilities.

 Subpart 623.3_Hazardous Material Identification andMaterial Safety Data


Sec. 623.302-70  Policy.

                Subpart 623.4_Use of Recovered Materials


Sec. 623.400  Scope of subpart.

Sec. 623.404  Procedures.

                    Subpart 623.5_Drug	Free Workplace


Sec. 623.506  Suspension of payments, termination of contract, and 
          debarment and suspension actions.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26172, July 11, 1988, unless otherwise noted.

         Subpart 623.1_Pollution Control and Clean Air and Water



Sec. 623.104  Exemptions.

    The Procurement Executive is the agency head for the purposes of FAR 
23.104(c).



Sec. 623.107  Compliance responsibilities.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 23.107.

[[Page 317]]

Subpart 623.3_Hazardous Material Identification and Material Safety Data



Sec. 623.302-70  Policy.

    Any work which affects the safety and/or health of post personnel, 
including the handling of hazardous materials, shall comply with the 
applicable requirements of the Department of State Safety/Health and 
Environmental Management Resource Guide (6 FAM 606.7). Requirements 
offices shall ensure that any contractor operations and activities, 
whether sponsored by the post or other Department organization, are 
closely coordinated with the Post Occupational Safety and Health Officer 
during both planning and implementation phases.

[59 FR 66760, Dec. 28, 1994]

                Subpart 623.4_Use of Recovered Materials

    Source: 64 FR 43626, Aug. 11, 1999, unless otherwise noted.



Sec. 623.400  Scope of subpart.

    The affirmative procurement program is applicable to all domestic 
acquisitions of items currently designated by an EPA guideline or by 
future guidelines promulgated by EPA. The requirements of this section 
are not applicable to acquisitions made and/or performed outside the 
United States or its possessions.



Sec. 623.404  Procedures.

    (b)(2) The requirements office initiating an acquisition is 
responsible for determining whether recovered materials should be 
included in the specifications. Requirements offices may purchase EPA 
designated items containing other than recovered materials only if one 
of the exemptions listed in FAR 23.404(b)(3) applies. If the 
requirements office determines to acquire EPA designated items that do 
not contain recovered materials, a written justification must be 
submitted to the head of the contracting activity.
    (i) Contracts for the purchase of, or requiring the supply of, any 
EPA designated item shall require that the item conform to the EPA 
guidelines, unless an exception has been approved by the head of the 
contracting activity in accordance with FAR 23.404(b)(3) and DOSAR 
623.404(b)(3).
    (ii) Contracting officers shall promote the fact that the Department 
is seeking to buy items containing recovered materials at pre-bid and 
pre-proposal conferences, when appropriate. Other means of promotion may 
include a specific notice on a solicitation's cover letter, calling 
attention to the requirement for recovered materials.
    (iii) Contracting officers shall include FAR clause 52.223-9 to 
ensure that contractors estimate, certify, and verify the amount of 
recovered material used in the performance of the contract.
    (iv) The effectiveness of the program shall be reviewed annually by 
A/OPE. An assessment will be made to determine if greater use of 
recovered materials is possible for the existing requirements or if 
recovered materials are causing undue delay, lack of competition, 
unreasonable prices, or an unacceptable level of performance.
    (3) The head of the contracting activity is the agency head for the 
purpose of FAR 23.404(b)(3).

                    Subpart 623.5_Drug-Free Workplace



Sec. 623.506  Suspension of payments, termination of contract, and 
          debarment and suspension actions.

    The authority to approve the determination prescribed in FAR 
23.506(e) is reserved to the Secretary of State.

[55 FR 5775, Feb. 16, 1990]

        PART 624_PROTECTION OF PRIVACY AND FREEDOM OF INFORMATION

    Authority: 22 U.S.C. 2658; 40 U.S.C. 486(c); 48 CFR Subpart 1.3.

                Subpart 624.2_Freedom of Information Act



Sec. 624.202  Policy.

    DOS regulations implementing the Freedom of Information Act (5 
U.S.C.

[[Page 318]]

552), as amended, are codified in Chapter 1, Department of State, 
Subchapter R, Access to Information, Part 171, Availability of 
information and records to the public, of Title 22 of the Code of 
Federal Regulations (22 CFR Part 171).

[53 FR 26172, July 11, 1988]

                      PART 625_FOREIGN ACQUISITION

                 Subpart 625.1_Buy American Act_Supplies

Sec.

Sec. 625.102  Policy.

Sec. 625.105  Evaluating offers.

Sec. 625.108  Excepted articles, materials, and supplies.

          Subpart 625.2_Buy American Act_Construction Materials


Sec. 625.202  Policy.

Sec. 625.203  Evaluating offers.

Sec. 625.204  Violations.

                Subpart 625.3_Balance of Payments Program


Sec. 625.300  Scope of subpart.

Sec. 625.300-70  Overseas acquisitions.

Sec. 625.302  Policy.

Sec. 625.304  Excess and near-excess foreign currencies.

         Subpart 625.7_Restrictions on Certain Foreign Purchases


Sec. 625.703  Exceptions.

        Subpart 625.70_Arab League Boycott and Related Provisions


Sec. 625.7001  Policy.

Sec. 625.7002  Solicitation provision and contract clause.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26172, July 11, 1988, unless otherwise noted.

                 Subpart 625.1_Buy American Act_Supplies



Sec. 625.102  Policy.

    (a)(3) The authority to make the determination prescribed in FAR 
25.102(a)(3) is delegated, without power of redelegation, to the head of 
the contracting activity.
    (b)(2) The authority to make the determination prescribed in FAR 
25.102(b)(2) is delegated, without power of redelegation, to the head of 
the contracting activity.

[59 FR 66762, Dec. 28, 1994]



Sec. 625.105  Evaluating offers.

    The authority to make the determinations prescribed in FAR 25.105 is 
delegated, without power of redelegation, to the head of the contracting 
activity.



Sec. 625.108  Excepted articles, materials, and supplies.

    A/OPE is the DOS central agency control point for furnishing to the 
appropriate FAR Council the documentation prescribed in FAR 15.108(b) 
and (c).

[53 FR 26172, July 11, 1988, as amended at 59 FR 66762, Dec. 28, 1994]

          Subpart 625.2_Buy American Act_Construction Materials



Sec. 625.202  Policy.

    (a)(2) The authority to make the determination prescribed in FAR 
25.202(a)(2) is delegated, without power of redelegation, to the head of 
the contracting activity.
    (b) The authority to make the determination prescribed in FAR 
25.202(b) is delegated, without power of redelegation, to the head of 
the contracting activity.

[59 FR 66762, Dec. 28, 1994]



Sec. 625.203  Evaluating offers.

    The head of the contracting activity is the agency head for the 
purposes of FAR 25.203 (a) and (b).

[59 FR 66762, Dec. 28, 1994]



Sec. 625.204  Violations.

    The Procurement Executive is the agency head for the purposes of FAR 
25.204.

                Subpart 625.3_Balance of Payments Program



Sec. 625.300  Scope of subpart.



Sec. 625.300-70  Overseas acquisitions.

    This program applies to acquisitions of supplies and services for 
use outside the United States regardless of the contractor's location.

[[Page 319]]



Sec. 625.302  Policy.

    The authority to make the determination prescribed in FAR 
25.302(b)(3) is delegated, without power of redelegation, to the head of 
the contracting activity. The authority prescribed in FAR 25.302(c) is 
delegated, without power of redelegation, to the head of the contracting 
activity.



Sec. 625.304  Excess and near-excess foreign currencies.

    The authority to make the determination prescribed in FAR 25.304(c) 
is delegated to the head of the contracting activity without power of 
redelegation.

[53 FR 26172, July 11, 1988, as amended at 59 FR 66762, Dec. 28, 1994]

         Subpart 625.7_Restrictions on Certain Foreign Purchases



Sec. 625.703  Exceptions.

    The authority to approve exceptions for other contracts in excess of 
the simplified acquisition threshold is delegated, without power of 
redelegation, o the head of the contracting activity.

[60 FR 39663, Aug. 3, 1995]

        Subpart 625.70_Arab League Boycott and Related Provisions

    Source: 64 FR 43626, Aug. 11, 1999, unless otherwise noted.



Sec. 625.7001  Policy.

    (a) Section 565 of the Fiscal Year 94/95 Foreign Relations 
Authorizations Act (Public Law 103-236) prohibits the Department of 
State from entering into any contract that expends funds appropriated to 
the Department of State:
    (1) With a foreign person that complies with the Arab League Boycott 
of Israel; or,
    (2) With any foreign or United States person that discriminates in 
the award of subcontracts on the basis of religion.
    (b) This authority has continuing effect. Section 565 requires 
specific language to be included in all Invitations for Bids and 
Requests for Proposals with respect to a contract subject to Section 
565's prohibitions.
    (c) Section 565 may be waived on a country-by-country basis if such 
a waiver is in the national interest and necessary to carry on 
diplomatic functions and is approved by the Secretary of State or his/
her designee.



Sec. 625.7002  Solicitation provision and contract clause.

    Contracting officers shall include the following provision and 
clause in all solicitations and contracts exceeding the simplified 
acquisition threshold, unless a waiver has been granted in accordance 
with DOSAR 625.7001(c):
    (a) 652.225-70, Arab League Boycott of Israel; and.
    (b) 652.225-71, Section 8(a) of the Export Administration Act, as 
amended.

                  PART 626_OTHER SOCIOECONOMIC PROGRAMS

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 64 FR 43627, Aug. 11, 1999, unless otherwise noted.

               Subpart 626.2_Minority Business Enterprise



Sec. 626.200-70  Solicitation provision.

    The contracting officer shall insert the provision at 652.226-70, 
Certification of Status as a Minority Business Enterprise, in all 
solicitations issued by domestic contracting activities. If the 
solicitation is being issued using electronic commerce, the contracting 
officer shall use the provision with its Alternate I.

[[Page 320]]



              SUBCHAPTER E_GENERAL CONTRACTING REQUIREMENTS

                 PART 627_PATENTS, DATA, AND COPYRIGHTS

                          Subpart 627.2_Patents

Sec.

Sec. 627.203  Patent indemnification of Government by contractor.

Sec. 627.203-6  Clause for Government waiver of indemnity.

         Subpart 627.3_Patent Rights Under Government Contracts


Sec. 627.303  Contract clauses.

Sec. 627.304  Procedures.

Sec. 627.304-1  General.

Sec. 627.304-5  Appeals.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 59 FR 66763, Dec. 28, 1994, unless otherwise noted.

                          Subpart 627.2_Patents



Sec. 627.203  Patent indemnification of Government by contractor.



Sec. 627.203-6  Clause for Government waiver of indemnity.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 27.203-6.

         Subpart 627.3_Patent Rights Under Government Contracts



Sec. 627.303  Contract clauses.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 27.303. Determinations issued by the Procurement 
Executive shall be reviewed by the Office of the Legal Adviser.



Sec. 627.304  Procedures.



Sec. 627.304-1  General.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 27.304-1. Questions regarding fact-finding procedures as 
specified in FAR 27.304-1(a)(4) shall be referred to A/OPE. 
Determinations issued by the Procurement Executive shall be reviewed by 
the Office of the Legal Adviser.



Sec. 627.304-5  Appeals.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 27.304-5. Questions regarding the appeals procedure as 
specified in FAR 27.304-5(b) shall be referred to A/OPE.

                      PART 628_BONDS AND INSURANCE

                           Subpart 628.1_Bonds

Sec.

Sec. 628.101  Bid guarantees.

Sec. 628.101-1  Policy on use.

Sec. 628.106-6  Furnishing information.

                         Subpart 628.2_Sureties


Sec. 628.203  Acceptability of individual surety.

Sec. 628.203-7  Exclusion of individual sureties.

                         Subpart 628.3_Insurance


Sec. 628.305  Overseas workers' compensation and war-hazard insurance.

Sec. 628.306  Insurance under fixed-price contracts.

Sec. 628.307  Insurance under cost-reimbursement contracts.

                     Subpart 628	70_Indemnification


Sec. 628.7001  DOSAR contract clause.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26173, July 11, 1988, unless otherwise noted.

                           Subpart 628.1_Bonds

    Source: 59 FR 66763, Dec. 28, 1994, unless otherwise noted.



Sec. 628.101  Bid guarantees.



Sec. 628.101-1  Policy on use.

    (c) The Procurement Executive is the agency head's designee for the 
purposes of FAR 28.101-1(c).



Sec. 628.106-6  Furnishing information.

    (c) The head of the contracting activity is the agency head's 
designee for the purposes of FAR 28.106-6(c).

[[Page 321]]

                         Subpart 628.2_Sureties



Sec. 628.203  Acceptability of individual surety.

    (g) Evidence of possible criminal or fraudulent activities by an 
individual surety shall be referred to the Office of the Inspector 
General.

[59 FR 66763, Dec. 28, 1994]



Sec. 628.203-7  Exclusion of individual sureties.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 28.203-7.

[59 FR 66763, Dec. 28, 1994]

                         Subpart 628.3_Insurance

    Source: 59 FR 66763, Dec. 28, 1994, unless otherwise noted.



Sec. 628.305  Overseas workers' compensation and war-hazard insurance.

    (a) It is the Department's policy that acquisitions for services, 
including construction but excluding personal services contracts, which 
require contractor personnel to perform work outside of the United 
States, shall include the contractual obligation for coverage under the 
Defense Base Act (42 U.S.C. Sections 1651-1654, as amended). For the 
purpose of this section only, ``contractor personnel'' includes 
individuals who are either:
    (1) United States citizens or residents, or
    (2) Hired in the United States or its possessions.
    (b) The Department of State has entered into a contract with an 
insurance broker and carrier to provide Defense Base Act insurance, at a 
fixed rate for services and construction, to cover DOS contracts which 
will require performance overseas by United States citizens, residents, 
or those employed in the United States. In countries where local 
nationals and/or third country nationals will be employed to perform the 
contract, such countries have been waived by the Secretary of Labor. 
Whenever such insurance is required under the contract, the contracting 
officer shall insert the clause at 652.228-71, Worker's Compensation 
Insurance (Defense Base Act)--Services. If the contract is for 
construction, the contracting officer shall insert the clause with its 
Alternate I.
    (c) Upon award of a contract which requires Defense Base Act 
insurance, the contracting officer shall notify the successful offeror 
of the name of the insurance broker from which the contractor should 
acquire insurance.
    (d) The authority to request a waiver from the Secretary of Labor of 
a particular country, as set forth in FAR 28.305(d), is reserved to the 
Secretary of State. The Department has obtained blanket waivers from the 
Secretary of Labor for all contracts for services, including 
construction, awarded and/or performed overseas. The waivers apply to 
all individuals who are not employees hired in the United States, or who 
are not United States citizens or residents.

[59 FR 66763, Dec. 28, 1994, as amended at 64 FR 43627, Aug. 11, 1999]



Sec. 628.306  Insurance under fixed-price contracts.

    The contracting officer shall insert the provision at 652.228-74, 
Defense Base Act Insurance Rates--Limitation--Fixed-Price, in 
solicitations for fixed-price or construction contracts to be performed 
outside the United States by United States citizens, residents, and/or 
those hired in the United States.

[64 FR 43627, Aug. 11, 1999]



Sec. 628.307  Insurance under cost-reimbursement contracts.

    The contracting officer shall insert the provision at 652.228-76, 
Defense Base Act Insurance Rates--Limitation--Cost-Reimbursement, Labor-
Hour, and Time-and-Materials, in solicitations for cost-reimbursement, 
labor-hour, or time-and-materials type contracts to be performed outside 
the United States by United States citizens, residents, and/or those 
hired in the United States.

[64 FR 43627, Aug. 11, 1999]

                     Subpart 628	70_Indemnification



Sec. 628.7001  DOSAR contract clause.

    (a) Contractors should not ordinarily be required to assume risks 
which a

[[Page 322]]

private buyer would guard against through insurance. There may be 
occasions, however, when a contractor's assumption of such risks is in 
the best interest of the Government. The clause in paragraph (b) below 
is authorized for use on those occasions. In the determination of its 
use, the contracting officer should weigh the advantages it provides 
against the likelihood of a resultant increase in the contract price.
    (b) The contracting officer shall insert the clause at 652.228-70, 
Indemnification, in solicitations and contracts when it is determined 
that the contractor's assumption of risk is in the best interest of the 
Government.

                             PART 629_TAXES

                          Subpart 629.1_General

Sec.

Sec. 629.101  Resolving tax problems.

                   Subpart 629.2_Federal Excise Taxes


Sec. 629.202  General exemptions.

Sec. 629.202-70  Exemption from other Federal taxes.

                   Subpart 629.3_State and Local Taxes


Sec. 629.302  Application of State and local taxes to the Government.

Sec. 629.303  Application of State and local taxes to Government 
          contractors and subcontractors.

                     Subpart 629.4_Contract Clauses


Sec. 629.401  Domestic contracts.

Sec. 629.401-70  DOSAR contract clause.

Sec. 629.402  Foreign contracts.

Sec. 629.402-1  Foreign fixed-price contracts.

Sec. 629.402-1-70  DOSAR contract clause.

    Authority: 22 U.S.C. 2658; 40 U.S.C. 486(c); 48 CFR Subpart 1.3.

    Source: 53 FR 26173, July 11, 1988, unless otherwise noted.

                          Subpart 629.1_General



Sec. 629.101  Resolving tax problems.

    In certain instances, acquisitions by posts are exempt from various 
taxes in foreign countries. Contracting officers shall ascertain such 
exemptions and take maximum advantage of them.

                   Subpart 629.2_Federal Excise Taxes



Sec. 629.202  General exemptions.



Sec. 629.202-70  Exemptions from other Federal taxes.

    Taxable articles purchased for presentation abroad as gifts to 
foreign dignitaries and taxable articles purchased for presentation as 
gifts to foreign dignitaries visiting in the United States but which are 
to be taken out of the United States may be exempt from retail taxes or 
manufacturers excise taxes, in accordance with the letter of October 18, 
1963, from the Chief, Excise Tax Branch, Internal Revenue Service.

                   Subpart 629.3_State and Local Taxes



Sec. 629.302  Application of State and local taxes to the Government.

    The Office of the Legal Adviser is the agency-designated counsel for 
the purposes of FAR 29.302(a).



Sec. 629.303  Application of State and local taxes to Government 
          contractors and subcontractors.

    The authority to make the determination prescribed in FAR 29.303(a) 
is delegated, without power of redelegation, to the head of the 
contracting activity (see 601.603-70). The Office of the Legal Adviser 
is the agency-designated counsel for the purposes of FAR 29.303(c).

                     Subpart 629.4_Contract Clauses



Sec. 629.401  Domestic contracts.



Sec. 629.401-70  DOSAR contract clause.

    The contracting officer shall insert the clause at 652.229-71, 
Excise Tax Exemption Statement for Contractors Within the United States, 
in solicitations and contracts if the prospective contractor is located 
inside the United States and the acquisition involves export of supplies 
to an overseas post.

[[Page 323]]



Sec. 629.402  Foreign contracts.



Sec. 629.402-1  Foreign fixed-price contracts.



Sec. 629.402-1-70  DOSAR contract clause.

    The contracting officer shall insert the clause at 652.229-71, 
Personal Property Disposition at Posts Abroad, in all solicitations and 
contracts performed overseas.

[64 FR 43627, Aug. 11, 1999]

            PART 631_CONTRACT COST PRINCIPLES AND PROCEDURES

                       Subpart 631.1_Applicability

Sec.

Sec. 631.101  Objectives.

          Subpart 631.2_Contracts with Commercial Organizations


Sec. 631.205  Selected costs.

Sec. 631.205-6  Compensation for personal services.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 59 FR 66764, Dec. 28, 1994, unless otherwise noted.

                       Subpart 631.1_Applicability



Sec. 631.101  Objectives.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 31.101.

          Subpart 631.2_Contracts with Commercial Organizations



Sec. 631.205  Selected costs.



Sec. 631.205-6  Compensation for personal services.

    (g)(3) The head of the contracting activity is the agency head's 
designee for the purpose of FAR 31.205-6(g)(3).

[64 FR 43627, Aug. 11, 1999]

                       PART 632_CONTRACT FINANCING

Sec.

Sec. 632.006  Reduction or suspension of contract payments upon finding 
          of fraud.

Sec. 632.006-1  General.

Sec. 632.006-2  Definitions.

Sec. 632.006-4  Procedures.

          Subpart 632.1_Non-Commercial Item Purchase Financing


Sec. 632.114  Unusual contract financing.

            Subpart 632.2_Commercial Item Purchase Financing


Sec. 632.201  Statutory authority.

                     Subpart 632.4_Advance Payments


Sec. 632.402  General.

Sec. 632.404  Exclusions.

Sec. 632.407  Interest.

                     Subpart 632.7_Contract Funding


Sec. 632.702  Policy.

Sec. 632.702-70  DOS policy.

Sec. 632.703  Contract funding requirements.

Sec. 632.703-3  Contracts crossing fiscal years.

Sec. 632.705  Contract clauses.

Sec. 632.705-70  DOSAR contract clause.

                   Subpart 632.8_Assignment of Claims


Sec. 632.803  Policies.

                      Subpart 632.9_Prompt Payment


Sec. 632.903  Policy.

Sec. 632.908  Contract clauses.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26173, July 11, 1988, unless otherwise noted.



Sec. 632.006  Reduction or suspension of contract payments upon finding 
          of fraud.



Sec. 632.006-1  General.

    The Procurement Executive is the agency head for the purpose of FAR 
32.006-1.

[64 FR 43627, Aug. 11, 1999]



Sec. 632.006-2  Definitions.

    Remedy coordination official means the Assistant Inspector General 
for Investigations.

[64 FR 43627, Aug. 11, 1999]



Sec. 632.006-4  Procedures.

    The Procurement Executive is the agency head for the purposes of FAR 
32.006-4.

[64 FR 43627, Aug. 11, 1999]

[[Page 324]]

          Subpart 632.1_Non-Commercial Item Purchase Financing



Sec. 632.114  Unusual contract financing.

    The Procurement Executive is the agency head for the purpose of FAR 
32.114.

[64 FR 43627, Aug. 11, 1999]

            Subpart 632.2_Commercial Item Purchase Financing



Sec. 632.201  Statutory authority.

    The head of the contracting activity is the agency head for the 
purpose of FAR 32.201.

[64 FR 43627, Aug. 11, 1999]

                     Subpart 632.4_Advance Payments



Sec. 632.402  General.

    (b) Advance payments shall be authorized sparingly. Contracting 
officers should consider the use of partial payments, fast payments, or 
more frequent payments as alternatives to advance payments.
    (c)(1)(iii) The authority to make the determination prescribed in 
FAR 32.402(c)(1)(iii) is delegated, without power of redelegation, to 
the head of the contracting activity (see 601.603-70). For acquisitions 
by overseas posts, the head of the contracting activity shall obtain the 
concurrence of the Procurement Executive before making a determination 
pursuant to this section.

[53 FR 26173, July 11, 1988, as amended at 59 FR 66764, Dec. 28, 1994]



Sec. 632.404  Exclusions.

    (a) Total advance payments may be authorized for the items listed in 
FAR 32.404(a), notwithstanding their designation as a commercial item 
and acquisition under FAR part 12 procedures.

[64 FR 43627, Aug. 11, 1999]



Sec. 632.407  Interest.

    (d) The Procurement Executive is the agency head's designee for the 
purposes of FAR 32.407(d).

[59 FR 66764, Dec. 28, 1994]

                     Subpart 632.7_Contract Funding

    Source: 64 FR 43628, Aug. 11, 1999, unless otherwise noted.



Sec. 632.702  Policy.



Sec. 632.702-70  DOS policy.

    The Department's policy is to provide full funding for all 
contracts, to the maximum extent practicable. FAR 32.704 and 32.705-2 
provide for incremental funding of cost-reimbursement contracts. Fixed-
price, labor-hour, and time-and-materials contracts for severable 
services may also be incrementally funded if full funding is not 
available at the time of contract award and the contracting officer 
executes a determination and findings, approved by the requirements 
office, justifying the need for incremental funding due to the 
unavailability of funds.



Sec. 632.703  Contract funding requirements.



Sec. 632.703-3  Contracts crossing fiscal years.

    (b) The head of the contracting activity is the agency head for the 
purpose of FAR 32.703-3(b).



Sec. 632.705  Contract clauses.



Sec. 632.705-70  DOSAR contract clause.

    The contracting officer shall insert the clause at 652.232-72, 
Limitation of Funds, in incrementally funded fixed-price, labor-hour, 
and time-and-materials solicitations and contracts for severable 
services.

                   Subpart 632.8_Assignment of Claims



Sec. 632.803  Policies.

    (b) The assignment of claims shall be prohibited for all personal 
services contracts. The assignment of claims shall also be prohibited 
for all contracts awarded and performed overseas, unless approval is 
received from the Procurement Executive. The Directors, Regional 
Procurement Support Offices may approve the assignment of claims

[[Page 325]]

for contracts under their administration after obtaining legal 
consultation.

[59 FR 66764, Dec. 28, 1994, as amended at 64 FR 43628, Aug. 11, 1999]

                      Subpart 632.9_Prompt Payment



Sec. 632.903  Policy.

    The authority to make the determination prescribed in FAR 32.903 is 
delegated, without power of redelegation, to the head of the contracting 
activity. Before making a determination concerning early invoice and 
contract financing payments, the head of the contracting activity shall 
consult with the Office of Fiscal Operations director, or designee.

[55 FR 5775, Feb. 16, 1990]



Sec. 632.908  Contract clauses.

    (a) The contracting officer may insert a clause substantially the 
same as the clause at 652.232-70, Payment Schedule and Invoice 
Submission (Fixed-Price), in fixed-price type solicitations and 
contracts.
    (b) The contracting officer may insert a clause substantially the 
same as the clause at 652.232-71, Voucher Submission (cost-
Reimbursement), in cost-reimbursement type solicitations and contracts.

[59 FR 66764, Dec. 28, 1994]

                PART 633_PROTESTS, DISPUTES, AND APPEALS

                         Subpart 633.1_Protests

Sec.

Sec. 633.102  General.

Sec. 633.103  Protests to the agency.

Sec. 633.104  Protests to GAO.

                   Subpart 633.2_Disputes and Appeals


Sec. 633.203  Applicability.

Sec. 633.214-70  Alternative dispute resolution.

Sec. 633.270  Disputes and appeals under DOS contracts subject to the 
          Contract Disputes Act of 1978.

Sec. 633.270-1  Scope of section.

Sec. 633.270-2  Designation.

Sec. 633.270-3  DOS support.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26173, July 11, 1988, unless otherwise noted.

                         Subpart 633.1_Protests



Sec. 633.102  General.

    All communications relative to protests filed with the General 
Accounting Office (GAO) shall be coordinated with the Office of the 
Legal Adviser.

[53 FR 26173, July 11, 1988, as amended at 64 FR 43628, Aug. 11, 1999]



Sec. 633.103  Protests to the agency.

    (d)(4) The independent review as described in FAR 33.103(d)(4) shall 
be performed by the Departmental Competition Advocate.

[64 FR 43628, Aug. 11, 1999]



Sec. 633.104  Protests to GAO.

    (a) General procedures. The Office of the Assistant Legal Adviser 
for Buildings and Acquisitions (L/BA) coordinates the response of the 
Department of State to protests filed at the GAO. Contracting activities 
shall consult L/BA for guidance before taking any actions in response to 
a protest to GAO.

[64 FR 43628, Aug. 11, 1999]

                   Subpart 633.2_Disputes and Appeals



Sec. 633.203  Applicability.

    The Procurement Executive is the agency head for the purposes of FAR 
33.203(b).



Sec. 633.214-70  Alternative dispute resolution.

    (a) Policy. The Department's goal is to resolve contract disputes 
before the issuance of a contracting officer's final decision under the 
Contract Disputes Act. Contracting officers shall consider all possible 
means of reaching a negotiated settlement, consistent with the 
Government's best interests, before issuing a final decision on a 
contractor claim under the process outlined in FAR 33.206 through 
33.211.
    (b) When to use ADR. (1) Factors favoring ADR. Contracting officers 
should consider using ADR in those cases where:
    (i) Only facts are in dispute;
    (ii) The facts are clearly not favorable to the Government;

[[Page 326]]

    (iii) The anticipated costs (in time and money) are less than the 
anticipated costs of litigation;
    (iv) Settlement attempts have reached an impasse;
    (v) ADR techniques have been used successfully in similar 
situations;
    (vi) There is a need for independent expert analysis; or,
    (vii) The claim has merit but its value is overstated.
    (2) Factors disfavoring ADR. The following circumstances do not 
favor use of ADR:
    (i) Cases involving disputes controlled by clear legal precedent, 
making compromise difficult;
    (ii) The resolution will have a significant impact on other pending 
cases or on the future conduct of Department business;
    (iii) The dispute is primarily over issues of law;
    (iv) A decision of precedential value is needed;
    (v) A significant policy question is involved;
    (vi) A full public record of the proceeding is important;
    (vii) The outcome could significantly involve persons who are not 
parties to the contract;
    (viii) The costs of pursuing an ADR procedure (in time and money) 
exceed the cost of litigation;
    (ix) The nature of the case may cause ADR to be used merely for 
delay or discovery; or,
    (x) The case involves criminal violations.
    (3) Initial action. Immediately upon receipt of a claim, the 
contracting officer shall send a letter acknowledging receipt of the 
claim and soliciting the contractor's views on submitting this claim for 
ADR. In every dispute, the first step toward resolution shall be 
unassisted negotiations, in which the parties try to work out the 
disagreement among themselves. If this fails, before issuing a final 
decision, the contracting officer shall consult first with the head of 
the contracting activity, and contact the Office of the Legal Adviser 
and A/OPE to determine whether the disagreement appears susceptible to 
resolution by ADR. Consideration shall be given to pursuing additional 
fact-finding or designating a neutral expert in the disputed issue to 
provide an advisory opinion.
    (c) Methods of ADR. If the initial action to resolve the dispute 
fails, and the contracting officer issues a final decision which is 
appealed, ADR may still be feasible. The GSBCA issues a notice regarding 
ADR to all contractors who file appeals under the Contract Disputes Act. 
This notice describes the following ADR techniques, which contracting 
officers are urged to discuss with contractors at any time:
    (1) Settlement judge. A settlement judge is either an administrative 
judge or hearing examiner who is appointed by the parties in dispute for 
the purpose of facilitating settlement. The agenda is flexible and based 
on the specifics of the individual dispute. By holding a frank, in-depth 
discussion of the strengths and weaknesses of each party's position, the 
settlement judge may be able to foster a settlement of the dispute. The 
settlement judge may meet with the parties jointly or individually, and 
the settlement judge's recommendations are not binding. Typically, the 
settlement judge's opinions, based on his or her experience in handling 
prior disputes, will help the parties realize whether their arguments 
have merit or not.
    (2) Minitrial. A minitrial is not an actual trial but rather a 
flexible, expedited, but structured procedure in which each party 
presents an abbreviated version of its position both to a neutral 
advisor (who may be appointed by the GSBCA) and to principals of the 
parties who have full contractual authority to conclude a settlement. 
The parties mutually decide on the form of presentation without regard 
to traditional judicial proceedings or rules of evidence. An advance 
agreement by the parties specifies the procedure to be followed in 
making presentations, as well as the role of the neutral advisor. Upon 
conclusion of the presentations, settlement negotiations are conducted. 
The neutral advisor may assist the parties in negotiating settlement, 
including making non-binding recommendations.
    (3) Summary trial with binding decision. A summary trial with 
binding decision is a procedure in which the scheduling

[[Page 327]]

of an appeal is expedited and the parties try their appeal informally 
before an administrative judge or panel of judges. The length of the 
trial and the time for presentation and decision are tailored to the 
needs of the particular case. Trial procedures and rules applicable to 
appeals are modified or eliminated to expedite resolution of the appeal. 
The parties must agree, however, that all decisions, rulings, and orders 
by the judge(s) are final, conclusive, and not appealable, and may not 
be set aside, except for fraud. A summary ``bench'' decision is issued 
at the conclusion of the trial or a summary written decision will be 
issued within ten (10) days of either the trial's conclusion or receipt 
of a trial transcript.
    (4) Mediation. Mediation is a process in which a neutral and 
impartial third party assists the Government and the contractor in 
conflict to negotiate an acceptable settlement of contested issues. The 
mediator is jointly selected and is asked by the disputing parties to 
assist them to reach a voluntary agreement. The mediator has no 
decisionmaking authority and cannot impose a decision. Mediation 
assistance involves working with the parties to improve their 
communications, clarify or interpret data, identify key issues to be 
discussed, design an effective negotiation process, generate settlement 
options, or help to identify or formulate areas of agreement. Additional 
information on alternative dispute resolution and mediation resources is 
available at the following address on the Internet: http://www.adrr.com
    (5) Arbitration. Non-binding arbitration is a process in which a 
dispute is jointly submitted by the Government and a contractor to an 
impartial and neutral person or panel who provides a written, non-
binding opinion used as a guide for negotiations toward a settlement. 
Although the Administrative Dispute Resolution Act of 1990 (Pub. L. 101-
552) allows agencies to use binding arbitration, the law provides that 
the agency head may vacate any arbitration award within 30 days after it 
is served on all parties. For this reason, non-binding arbitration is 
preferable. Additional information on alternative dispute resolution and 
mediation resources is available at the following address on the 
Internet: http://www.adrr.com
    (6) Partnering. Partnering involves an agreement in principle to 
share the risks involved in completing a project, and to establish and 
promote a partnership environment. Partnering itself is not a 
contractual agreement and it does not create any legally enforceable 
rights, but instead partnering seeks to create a new cooperative 
attitude in completing Government contracts. The three basic steps in 
partnering are:
    (i) Establish the new relationship through personal contact among 
the principals for the Government and the contractor before the work 
begins;
    (ii) Prepare a joint statement of goals establishing common 
objectives in specific detail for reaching the goals; and,
    (iii) Identify specific dispute prevention processes designed to 
head off problems, evaluate performance, and promote cooperation. 
Additional information on alternative dispute resolution and mediation 
resources is available at the following address on the Internet: http://
www.adrr.com
    (d) ADR procedures. The ADR method shall be selected voluntarily by 
both the Government and the contractor. Both parties shall agree on the 
procedures to be followed, including the agenda and amount of time 
allowed for each party to present its case. The parties may choose not 
to have a written transcript or hearing on the record, as this might 
inhibit settlement. Also, the decision rendered, if any, should not be 
considered to establish any precedent for future litigation unless the 
parties agree otherwise. In cases where the parties agree to pay jointly 
for a third-party neutral advisor, it is recommended that the parties 
and the advisor agree on a fair and reasonable price. The Government 
would then issue a simplified acquisition (if the dollar amount does not 
exceed the simplified acquisition limitation) for 50% of the agreed 
price, and the advisor would submit separate invoices (each for 50% of 
the price) to the Government and the contractor.

[59 FR 66764, Dec. 28, 1994, as amended at 64 FR 43628, Aug. 11, 1999]

[[Page 328]]



Sec. 633.270  Disputes and appeals under DOS contracts subject to the 
          Contract Disputes Act of 1978.



Sec. 633.270-1  Scope of section.

    This section concerns disputes relating to DOS contracts and the 
transfer of certain appellate and review functions from the Department 
of State to the General Services Board of Contract Appeals.

[53 FR 26173, July 11, 1988, as amended at 64 FR 43628, Aug. 11, 1999]



Sec. 633.270-2  Designation.

    The General Services Board of Contract Appeals (GSBCA) is the 
authorized representative of the Secretary of State and the Procurement 
Executive for the purposes of hearing and resolving disputes relating to 
DOS contracts subject to the Contract Disputes Act of 1978. The GSBCA 
shall hear and determine appeals by contractors from contracting 
officers' final decisions on disputed issues relating to DOS contracts 
subject to the Contract Disputes Act of 1978.

[53 FR 26173, July 11, 1988, as amended at 64 FR 43628, Aug. 11, 1999]



Sec. 633.270-3  DOS support.

    The Procurement Executive shall ensure the support of all DOS 
personnel in processing appeals before the GSBCA. The Procurement 
Executive is authorized to require such DOS officers and employees to 
cooperate for this purpose.

[53 FR 26173, July 11, 1988, as amended at 64 FR 43628, Aug. 11, 1999]

[[Page 329]]



             SUBCHAPTER F_SPECIAL CATEGORIES OF CONTRACTING

                    PART 634_MAJOR SYSTEM ACQUISITION

Sec.

Sec. 634.003  Responsibilities.

Sec. 634.005  General requirements.

Sec. 634.005-6  Full production.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26175, July 11, 1988, unless otherwise noted.



Sec. 634.003  Responsibilities.

    (a) The Procurement Executive is the agency head's designee for the 
purposes of FAR 34.003(a).
    (b) The Under Secretary for Management is the agency head for the 
purposes of FAR 34.003(c) and the acquisition executive for the purposes 
of A-109.

[53 FR 26175, July 11, 1988, as amended at 59 FR 66766, Dec. 28, 1994; 
64 FR 43628, Aug. 11, 1999]



Sec. 634.005  General requirements.



Sec. 634.005-6  Full production.

    The Deputy Secretary is the agency head for the purposes of FAR 
34.005-6 with power of redelegation to the Under Secretary for 
Management.

[59 FR 66766, Dec. 28, 1994, as amended at 64 FR 43628, Aug. 11, 1999]

         PART 636_CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS

                          Subpart 636.1_General

Sec.

Sec. 636.101  Applicability.

Sec. 636.101-70  Exception.

      Subpart 636.2_Special Aspects of Contracting for Construction


Sec. 636.209  Construction contracts with architect-engineer firms.

                     Subpart 636.5_Contract Clauses


Sec. 636.513  Accident prevention.

                Subpart 636.6_Architect-Engineer Services


Sec. 636.602  Selection of firms for architect-engineer contracts.

Sec. 636.602-1  Selection criteria.

Sec. 636.602-4  Selection authority.

Sec. 636.602-5  Short selection processes for contracts not to exceed 
          the simplified acquisition threshold.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26175, July 11, 1988, unless otherwise noted.

                          Subpart 636.1_General



Sec. 636.101  Applicability.



Sec. 636.101-70  Exception.

    Contracts for overseas construction, including capital improvements, 
alterations, and major repairs, may be excepted from the provisions of 
the FAR (48 CFR Ch. 1) under the authority of the Foreign Service 
Buildings Act, 1926, as amended, 22 U.S.C. 292 et seq., as further 
codified at section 474 of Title 40, Public Buildings, Property, and 
Works, of the U.S. Code. The Deputy Assistant Secretary for Foreign 
Buildings Operations is authorized to waive the provisions of the FAR.

[53 FR 26175, July 11, 1988, as amended at 59 FR 66766, Dec. 28, 1994; 
64 FR 43628, Aug. 11, 1999]

      Subpart 636.2_Special Aspects of Contracting for Construction



Sec. 636.209  Construction contracts with architect-engineer firms.

    The Procurement Executive is the head of the agency for the purposes 
of FAR 36.209.

                     Subpart 636.5_Contract Clauses



Sec. 636.513  Accident prevention.

    (a) In accordance with a class deviation approved by the Procurement 
Executive, contracting officers at overseas contracting activities shall 
insert DOSAR 652.236-70, Accident Prevention, in lieu of FAR clause 
52.236-13 when awarding construction contracts.

[64 FR 43628, Aug. 11, 1999]

[[Page 330]]

                Subpart 636.6_Architect-Engineer Services



Sec. 636.602  Selection of firms for architect-engineer contracts.



Sec. 636.602-1  Selection criteria.

    (b) The head of the contracting activity is the agency head's 
designee for the purpose of FAR 36.602-1(b).

[64 FR 43628, Aug. 11, 1999]



Sec. 636.602-4  Selection authority.

    (a) The final selection decision shall be made as designated by the 
Deputy Assistant Secretary for Foreign Buildings Operations for 
acquisitions issued by that office; the Director, Moscow Embassy 
Buildings Control Office, for Moscow chancery building(s) only; and, the 
appropriate head of the contracting activity for all other actions.

[59 FR 66766, Dec. 28, 1994]



Sec. 636.602-5  Short selection processes for contracts not to exceed 
          the simplified acquisition threshold.

    The short selection process described in FAR 36.602-5 is authorized 
for use for contracts not expected to exceed the simplified acquisition 
threshold.

[59 FR 66766, Dec. 28, 1994, as amended at 60 FR 39663, Aug. 3, 1995]

                      PART 637_SERVICE CONTRACTING

                 Subpart 637.1_Service Contracts_General

Sec.

Sec. 637.103  Contracting officer responsibility.

Sec. 637.104  Personal services contracts.

Sec. 637.104-70  Personal services contracts.

Sec. 637.110  Solicitation provisions and contract clauses.

             Subpart 637.2_Advisory and Assistance Services


Sec. 637.204  Guidelines for determining availability of personnel.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26176, July 11, 1988, unless otherwise noted.

                 Subpart 637.1_Service Contracts_General



Sec. 637.103  Contracting officer responsibility.

    The Office of the Legal Adviser is the DOS legal counsel for the 
purposes of FAR 37.103(a)(2).



Sec. 637.104  Personal services contracts.

    The Office of the Legal Adviser is the DOS legal counsel for the 
purposes of FAR 37.104(e).



Sec. 637.104-70  Personal services contracts.

    Pursuant to FAR 37.104(b), DOS statutory authorities for personal 
services contracts are--
    (a) For the Department, section 2(c) of the State Department Basic 
Authorities Act of 1956, as amended (22 U.S.C. 2669);
    (b) For the Bureau of Population, Refugees, and Migration, section 
5(a)(6) of the Migration and Refugee Assistance Act of 1962, as amended 
(22 U.S.C. 2605);
    (c) For the Bureau for International Narcotics and Law Enforcement 
Affairs, section 636(a)(3) of the Foreign Assistance Act of 1961, as 
amended (22 U.S.C. 2396);
    (d) For the Foreign Service Institute, section 704(a)(4) of the 
Foreign Service Act of 1980, as amended (22 U.S.C. 4024);
    (e) For the Office of Foreign Missions, section 208(d) of Title II--
Authorities Relating to the Regulation of Foreign Missions, of the State 
Department Basic Authorities Act of 1956, as amended (22 U.S.C. 4308);
    (f) For the Office of Foreign Buildings and the Moscow Embassy 
Control Office, section 5 of the Foreign Service Buildings Act, 1926, as 
amended (22 U.S.C. 296);
    (g) For the U.S. Mission to the United Nations, section 7 of the 
United Nations Participation Act of 1945, as amended (22 U.S.C. 287e);
    (h) For the Bureau of International Organization Affairs, the 
separate State Department appropriations acts; and
    (i) For the Bureau of Diplomatic Security, section 206 of Public Law 
99-399,

[[Page 331]]

as amended by the Emergency Supplemental Appropriations Act of 1998.

[53 FR 26176, July 11, 1988, as amended at 59 FR 66766, Dec. 28, 1994; 
60 FR 39663, Aug. 3, 1995; 64 FR 43629, Aug. 11, 1999]



Sec. 637.110  Solicitation provisions and contract clauses.

    (a) The contracting officer shall insert the clause at 652.237-70, 
Compensatory Time Off, in personal services contracts awarded in support 
of International Narcotics Control programs overseas, if the contracting 
officer determines its use appropriate.
    (b) The contracting officer shall insert the clause at 652.237-71, 
Identification/Building Pass, in all solicitations and contracts where 
contractor personnel require frequent and continuing access to 
Department of State facilities.
    (c) The contracting officer shall insert a clause substantially the 
same as the clause at 652.237-72, Observance of Legal Holidays and 
Administrative Leave, in all solicitations and contracts where 
contractor personnel will be working on-site in any Department of State 
facility. Overseas contracting activities may add local holidays to the 
list included in paragraph (a) of the clause.

[59 FR 66766, Dec. 28, 1994, as amended at 64 FR 43629, Aug. 11, 1999]

             Subpart 637.2_Advisory and Assistance Services



Sec. 637.204  Guidelines for determining availability of personnel.

    The head of the contracting activity is the agency head for the 
purposes of FAR 37.204.

[64 FR 43629, Aug. 11, 1999]

                PART 641_ACQUISITION OF UTILITY SERVICES

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 64 FR 43629, Aug. 11, 1999, unless otherwise noted.

                Subpart 641.2_Acquiring Utility Services



Sec. 641.201  Policy.

    (d) The Procurement Executive is the agency head for the purposes of 
FAR 41.201(d)(2)(i) and FAR 41.201(d)(3).

[[Page 332]]



                    SUBCHAPTER G_CONTRACT MANAGEMENT

           PART 642_CONTRACT ADMINISTRATION AND AUDIT SERVICES

             Subpart 642.2_Contract Administration Services

Sec.

Sec. 642.270  Contracting Officer's Representative (COR).

Sec. 642.271  DOSAR contract clauses.

       Subpart 642.6_Corporate Administration Contracting Officer


Sec. 642.602  Assignment and location.

                    Subpart 642.7_Indirect Cost Rates


Sec. 642.703  General.

Sec. 642.703-2  Certificate of indirect costs.

          Subpart 642.14_Traffic and Transportation Management


Sec. 642.1406-2  Contract clause.

Sec. 642.1406-2-70  DOSAR contract clauses.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26176, July 11, 1988, unless otherwise noted.

             Subpart 642.2_Contract Administration Services



Sec. 642.270  Contracting Officer's Representative (COR).

    (a) Scope. Contracting officers may designate technically qualified 
personnel as their authorized representatives to assist in the 
administration of contracts. This section is mandatory for domestic 
contracting activities and recommended for overseas contracting 
activities.
    (b) Policy. It is Department policy that only Department of State 
employees who have completed adequate training and have the necessary 
experience and judgment shall be appointed as CORs. This policy shall be 
reinforced by contracting officers and administered jointly by A/OPE and 
FSI. Required training shall be funded by the COR's office.

[59 FR 66766, Dec. 28, 1994]



Sec. 642.271  DOSAR contract clauses.

    (a) The contracting officer shall insert a clause substantially the 
same as the clause at 652.242-70, Contracting Officer's Representative, 
in solicitations and contracts when appointment of a contracting 
officer's representative is anticipated.
    (b) The contracting officer shall insert a clause substantially the 
same as the clause at 652.242-73, Authorization and Performance, in all 
solicitations and contracts to be awarded and/or performed overseas. For 
overseas local guard contracts, the contracting officer shall use the 
clause with its Alternate I.

[64 FR 43629, Aug. 11, 1999]

       Subpart 642.6_Corporate Administration Contracting Officer



Sec. 642.602  Assignment and location.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 42.602(a).

                    Subpart 642.7_Indirect Cost Rates



Sec. 642.703  General.



Sec. 642.703-2  Certificate of indirect costs.

    (b) The head of the contracting activity is the agency head's 
designee for the purpose of FAR 42.703-2(b).

[64 FR 43629, Aug. 11, 1999]

          Subpart 642.14_Traffic and Transportation Management



Sec. 642.1406-2  Contract clause.



Sec. 642.1406-2-70  DOSAR contract clauses.

    (a) The contracting officer shall insert the clause at 652.242-71, 
Notice of Shipment, in solicitations and contracts entered into and 
performed outside the United States, when overseas shipment of supplies 
is required.
    (b) The contracting officer shall insert the clause at 652.242-72, 
Shipping Instructions, in solicitations and contracts with a source in 
the United

[[Page 333]]

States and overseas shipment of supplies is required.

                     PART 643_CONTRACT MODIFICATIONS

                          Subpart 643.1_General

Sec.

Sec. 643.102  Policy.

Sec. 643.102-70  Contract compliance and review.

Sec. 643.104  Notification of contract changes.

Sec. 643.104-70  DOSAR contract clause.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26176, July 11, 1988, unless otherwise noted.

                          Subpart 643.1_General



Sec. 643.102  Policy.



Sec. 643.102-70  Contract compliance and review.

    When applicable, the contracting officer shall ensure the proposed 
contract modification complies with the competition requirements of FAR 
Part 6 and DOSAR Part 606.

[53 FR 26176, July 11, 1988, as amended at 59 FR 66767, Dec. 28, 1994; 
64 FR 43629, Aug. 11, 1999]



Sec. 643.104  Notification of contract changes.



Sec. 643.104-70  DOSAR contract clause.

    The contracting officer shall insert the clause at 652.243-70, 
Notices, in all solicitations and contracts exceeding the micro-purchase 
threshold which are awarded and/or performed overseas.

[64 FR 43629, Aug. 11, 1999]

             PART 644_SUBCONTRACTING POLICIES AND PROCEDURES

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 64 FR 43629, Aug. 11, 1999, unless otherwise noted.

          Subpart 644.3_Contractor's Purchasing System Reviews



Sec. 644.302  Requirements.

    (a) The Procurement Executive is the head of the agency for the 
purpose of FAR 44.302(a).

                      PART 645_GOVERNMENT PROPERTY

       Subpart 645.3_Providing Government Property to Contractors

Sec.

Sec. 645.302  Providing facilities.

Sec. 645.302-1  Policy.

     Subpart 645.4_Contractor Use and Rental of Government Property


Sec. 645.403  Rental--Use and Charges clause.

  Subpart 645.6_Reporting, Redistribution, and Disposal of Contractor 
                                Inventory


Sec. 645.608  Screening of contractor inventory.

Sec. 645.608-6  Waiver of screening requirements.

Sec. 645.610  Sale of surplus contractor inventory.

Sec. 645.610-2  Exemptions from sale by GSA.

    Authority: 22 U.S.C. 2658; 40 U.S.C. 486(c); 48 CFR Subpart 1.3.

    Source: 53 FR 26177, July 11, 1988, unless otherwise noted.

       Subpart 645.3_Providing Government Property to Contractors



Sec. 645.302  Providing facilities.



Sec. 645.302-1  Policy.

    The authority to make the determination prescribed in FAR 45.302-
1(a)(4) is delegated, without power of redelegation, to the head of the 
contracting activity (see 601.603-70).

[[Page 334]]

     Subpart 645.4_Contractor Use and Rental of Government Property



Sec. 645.403  Rental--Use and Charges clause.

    (a) The head of the contracting activity is the agency head's 
designee for the purpose of FAR 45.403(a).

[64 FR 43629, Aug. 11, 1999]

  Subpart 645.6_Reporting, Redistribution, and Disposal of Contractor 
                                Inventory



Sec. 645.608  Screening of contractor inventory.



Sec. 645.608-6  Waiver of screening requirements.

    The Procurement Executive is the agency head's designee for the 
purposes of FAR 45.608-6.



Sec. 645.610  Sale of surplus contractor inventory.



Sec. 645.610-2  Exemptions from sale by GSA.

    The Procurement Executive is the agency head for the purposes of FAR 
45.610-2(a).

                         PART 647_TRANSPORTATION

Sec.

Sec. 647.000  Scope of part.

Subpart 647.2_Contracts for Transportation or for Transportation-Related 
                                Services


Sec. 647.207  Solicitation provisions, contract clauses, and special 
          requirements.

Sec. 647.207-7  Liability and insurance.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 59 FR 66767, Dec. 28, 1994, unless otherwise noted.



Sec. 647.000  Scope of part.

    The FAR and DOSAR do not apply to the acquisition of transportation 
services via Government bill of lading (GBL) or other similar forms.

Subpart 647.2_Contracts for Transportation or for Transportation-Related 
                                Services



Sec. 647.207  Solicitation provisions, contract clauses, and special 
          requirements.



Sec. 647.207-7  Liability and insurance.

    (e) The Procurement Executive has approved a class deviation for 
paragraph (c) of FAR clause 52.247-23, Contractor Liability for Loss of 
and/or Damage to Household Goods. The contracting officer shall indicate 
that the contractor shall indemnify the owner of the goods at a rate of 
$5.00 per pound (or metric equivalent in local currency) based on the 
total net weight. The rate conforms with liability calculations found in 
International Through Government Bills of Lading (ITGBL).

[64 FR 43629, Aug. 11, 1999]

                       PART 648_VALUE ENGINEERING

    Authority: 22 U.S.C. 2658; 40 U.S.C. 486(c); 48 CFR 1.3.

                  Subpart 648.1_Policies and Procedures



Sec. 648.102  Policies.

    (a) The authority to grant exemptions prescribed in FAR 48.102(a), 
or to extend future contract savings or sharing pursuant to FAR 
48.102(g), is delegated, without power of redelegation, to the head of 
the contracting activity (see 601.603-70).

[55 FR 5775, Feb. 16, 1990]

                     Subpart 648.2_Contract Clauses



Sec. 648.201  Clauses for supply or service contracts.

    The authority to determine exemptions prescribed in FAR 48.201(a)(6) 
is delegated, without power of redelegation, to the head of the 
contracting activity.

[55 FR 5775, Feb. 16, 1990]

[[Page 335]]

                    PART 649_TERMINATION OF CONTRACTS

    Authority: 40 U.S.C. 485(c); 22 U.S.C. 2658.

    Source: 59 FR 66767, Dec. 28, 1994, unless otherwise noted.

                    Subpart 649.1_General Principles.



Sec. 649.106  Fraud or other criminal conduct.

    If the Termination Contracting Officer (TCO) suspects fraud or other 
criminal conduct related to the settlement of a terminated contract, the 
TCO shall discontinue negotiations and report the facts to the Office of 
the Inspector General.

            PART 651_USE OF GOVERNMENT SOURCES BY CONTRACTORS

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

   Subpart 651.70_Contractor Use of Travel Advances, Official Travel 
               Orders, and Government Travel Requisitions



Sec. 651.701  Policy.

    (a) It is the Department's policy that contractors shall not:
    (1) Receive travel advances from the Department for contract-related 
travel;
    (2) Travel under official travel orders; or,
    (3) Receive Government Travel Requisitions (GTRs) for 
transportation.
    (b) All contract-related travel shall be performed on the 
contractor's account with reimbursement provided after submission of a 
proper voucher.
    (c) This policy does not apply to personal services contractor; 
provided, that such contractors are paid through the Department's 
payroll system and they are subject to the standard payroll deductions 
of Federal Withholding Tax and FICA. It also does not apply to contracts 
awarded by the Office of Language Services (A/OPR/LS).

[59 FR 66767, Dec. 28, 1994]

[[Page 336]]



                     SUBCHAPTER H_CLAUSES AND FORMS

          PART 652_SOLICITATION PROVISIONS AND CONTRACT CLAUSES

Sec.

Sec. 652.000  Scope of part.

       Subpart 652.1_Instructions for Using Provisions and Clauses


Sec. 652.100  Scope of subpart.

Sec. 652.100-70  Policy.

Sec. 652.102  Incorporating provisions and clauses.

Sec. 652.102-1  Incorporation by reference.

              Subpart 652.2_Texts of Provisions and Clauses


Sec. 652.200  Scope of subpart.

Sec. 652.206-70  Competition Advocate/Ombudsman.

Sec. 652.216-70  Ordering--Indefinite-Delivery Contract.

Sec. 652.216-71  Price Adjustment.

Sec. 652.219-70  Department of State Subcontracting Goals.

Sec. 652.219-71  Section 8(a) Direct Awards.

Sec. 652.225-70  Arab League Boycott of Israel.

Sec. 652.225-71  Section 8(a) of the Export Administration Act of 1979, 
          as Amended.

Sec. 652.226-70  Certification of Status as a Minority Business 
          Enterprise.

Sec. 652.228-70  Indemnification.

Sec. 652.228-71  Worker's Compensation Insurance (Defense Base Act)--
          Services.

Sec. 652.228-72--652.228-73  [Reserved]

Sec. 652.228-74  Defense Base Act insurance rates--Limitation--Fixed-
          price.

Sec. 652.228-75  [Reserved]

Sec. 652.228-76  Defense Base Act Insurance Rates--Limitation--Cost-
          Reimbursement, Labor-Hour, and Time-and-Materials.

Sec. 652.229-70  Excise Tax Exemption Statement for Contractors Within 
          the United States.

Sec. 652.229-71  Personal Property Disposition at Posts Abroad.

Sec. 652.232-70  Payment Schedule and Invoice Submission (Fixed-Price).

Sec. 652.232-71  Voucher Submission (Cost-Reimbursement).

Sec. 652.232-72  Limitation of Funds.

Sec. 652.236-70  Accident Prevention.

Sec. 652.237-70  Compensatory time off.

Sec. 652.237-71  Identification/Building Pass.

Sec. 652.237-72  Observance of Legal Holidays and Administrative Leave.

Sec. 652.242-70  Contracting Officer's Representative (COR).

Sec. 652.242-71  Notice of Shipments.

Sec. 652.242-72  Shipping Instructions.

Sec. 652.242-73  Authorization and Performance.

Sec. 652.243-70  Notices.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26177, July 11, 1988, unless otherwise noted.



Sec. 652.000  Scope of part.

    This part sets forth solicitation provisions and contract clauses, 
in addition to those prescribed in FAR Part 52, for use in DOS 
acquisitions.

       Subpart 652.1_Instructions for Using Provisions and Clauses



Sec. 652.100  Scope of subpart.



Sec. 652.100-70  Policy.

    (a) The solicitation provisions and contract clauses in FAR Subpart 
52.2 or this Subpart 652.2 shall be used as prescribed therein, except 
when the use of any provision or clause is prohibited by or inconsistent 
with local laws, or the supplies or services could not be obtained if 
the provision or clause were to be included.
    (b) The contracting officer shall justify the exclusion of any 
provisions or clauses in accordance with FAR Subpart 1.4 and 601.470.



Sec. 652.102  Incorporating provisions and clauses.



Sec. 652.102-1  Incorporation by reference.

    The Procurement Executive is the agency head for the purposes of FAR 
52.102-1(a)(2)(ii).

              Subpart 652.2_Texts of Provisions and Clauses



Sec. 652.200  Scope of subpart.

    This subpart sets forth the text of all DOSAR provisions and 
clauses, and for each provision and clause provides a cross-reference to 
the location in the DOSAR that prescribes its use.



Sec. 652.206-70  Competition Advocate/Ombudsman.

    As prescribed in 606.570, insert the following provision:

[[Page 337]]

                Competition Advocate/Ombudsman (AUG 1999)

    (a) The Department of State's Competition Advocate is responsible 
for assisting industry in removing restrictive requirements from 
Department of State solicitations and removing barriers to full and open 
competition and use of commercial items. If such a solicitation is 
considered competitively restrictive or does not appear properly 
conducive to competition and commercial practices, potential offerors 
are encouraged to first contact the contracting officer for the 
respective solicitation. If concerns remain unresolved, contact the 
Department of State Competition Advocate on (703) 516-1680, by fax at 
(703) 875-6155, or write to: Department of State, Competition Advocate, 
Office of the Procurement Executive (A/OPE), Suite 603, SA-6, 
Washington, DC 20522-0602.
    (b) The Department of State's Acquisition Ombudsman has been 
appointed to hear concerns from potential offerors and contractors 
during the preaward and postaward phases of this acquisition. The role 
of the ombudsman is not to diminish the authority of the contracting 
officer, the Technical Evaluation Panel or Source Evaluation Board, or 
the selection official. The purpose of the ombudsman is to facilitate 
the communication of concerns, issues, disagreements, and 
recommendations of interested parties to the appropriate Government 
personnel, and work to resolve them. When requested and appropriate, the 
ombudsman will maintain strict confidentiality as to the source of the 
concern. The ombudsman does not participate in the evaluation of 
proposals, the source selection process, or the adjudication of formal 
contract disputes. Interested parties are invited to contact the 
contracting activity ombudsman, [insert name], at [insert telephone and 
fax numbers]. For an American Embassy or overseas post, refer to the 
numbers below for the Department Acquisition Ombudsman. Concerns, 
issues, disagreements, and recommendations which cannot be resolved at a 
contracting activity level may be referred to the Department of State 
Acquisition Ombudsman at (703) 516-1680, by fax at (703) 875-6155, or 
write to: Department of State, Acquisition Ombudsman, Office of the 
Procurement Executive (A/OPE), Suite 603, SA-6, Washington, DC 20522-
0602.

                           (End of provision)

[64 FR 43629, Aug. 11, 1999]



Sec. 652.216-70  Ordering--Indefinite-Delivery Contract.

    As prescribed in 616.506-70, insert the following clause:

           Ordering--Indefinite-Delivery Contracts (DEC 1994)

    The Government shall use one of the following forms to issue orders 
under this contract:
    (a) The Optional Form 347, Order for Supplies or Services, and 
Optional Form 348, Order for Supplies or Services Schedule--
Continuation; or,
    (b) The Optional Form 206, Purchase Order, Receiving Report and 
Voucher, and Optional Form 206A, Continuation Sheet.

                             (End of clause)

[53 FR 26177, July 11, 1988, as amended at 59 FR 66768, Dec. 28, 1994; 
64 FR 43630, Aug. 11, 1999]



Sec. 652.216-71  Price Adjustment.

    As prescribed in 616.203-4, insert a clause substantially the same 
as follows:

                       Price Adjustment (AUG 1999)

    (a) The contract price may be increased or decreased in actual costs 
of direct service labor which result directly from laws enacted and 
effective during the term of this contract by the [insert name of 
country] Government. Direct service labor costs include only the costs 
of wages and direct benefits (such as social security, health insurance, 
unemployment compensation insurance) paid to or incurred for the direct 
benefit of personnel performing services under one of the categories 
listed in Section [identify section number] of this contract. Price 
adjustments will include only changes in direct service labor costs 
incurred in order to comply with the requirements of the law. No 
adjustment will be made under this clause with respect to labor costs of 
personnel not performing direct service labor under the categories of 
Section [identify section], nor for overhead, profit, general and 
administrative (G&A) costs, taxes or any other costs whatsoever.
    (b) For the contracting officer to consider any request for 
adjustment, the contractor shall demonstrate in writing:
    (1) That the change in the law occurred during the term of this 
contract and subsequent to the award date of this contract; and,
    (2) That the change in the law could not have been reasonably 
anticipated prior to contract award; and,
    (3) How the change in the law directly affects the contractor's 
costs under this contract.
    (c) The contractor shall present data that clearly supports any 
request for adjustment. This data shall be submitted no later than 30 
calendar days after the changes in the law

[[Page 338]]

have been made public. This data shall include, but not be limited to, 
the following:
    (1) The calculation of the amount of adjustment requested; and,
    (2) Documentation which identifies and provides the appropriate 
portions of the text of the particular law from which the request is 
derived.
    (d) In order to establish the change between the requested adjusted 
rate and the original rate, the contractor shall support the appropriate 
data and composition of the original rate and the requested adjusted 
rate. This shall include details regarding specific hourly rates paid to 
individual employees. For contracts paid in U.S. dollars, the 
contractor's request for price adjustment shall present data reflecting:
    (1) The exchange rate in effect on the date of the contractor's 
proposal that was accepted for the basic contract; and
    (2) The current exchange rate and its effect on payment of workers 
in local currency. The allowable adjustment shall be limited to the 
extent to which increases in direct service labor costs due to host 
country law changes are not offset by exchange rate gains.
    (e) Only direct cost changes mandated by enacted laws shall be 
considered for adjustment under this contract. Changes for purposes of 
maintaining parity of pay between employees at the minimum mandated 
levels and employees already paid at levels above the newly mandated 
minimums shall not be considered. Therefore, if the contractor elects to 
increase payments to employees who are already being paid at or above 
the mandated amounts, such increased costs shall be borne solely by the 
contractor and shall not be justification for an increase in the hourly 
and monthly rates under this contract.
    (f) Any request for adjustment shall be presented by signature of an 
officer or general partner of the contractor having overall 
responsibility for the conduct of the contractor's affairs.
    (g) No adjustment shall be made to the contract price that relates 
to any indirect, overhead, or fixed costs, profit or fee. Only the 
changes in direct service labor wages (and any benefits based directly 
on wages) shall be considered by the U.S. Government as basis for 
contract price changes.
    (h) No request by the contractor for an adjustment under this clause 
shall be allowed if asserted after final payment has been made under 
this contract.
    (i) This clause shall only apply to laws enacted by the [insert name 
of country] Government meeting the criterion set forth above in 
paragraph (b). No adjustments shall be made due to currency fluctuations 
in exchange rates.

                             (End of clause)

[64 FR 43630, Aug. 11, 1999]



Sec. 652.219-70  Department of State Subcontracting Goals.

    As prescribed in 619.708-70, insert a provision substantially the 
same as follows:

           Department of State Subcontracting Goals (DEC 1994)

    (a) The offeror shall provide a Small, Small Disadvantaged and 
Woman-Owned Enterprise Subcontracting Plan that details its approach to 
selecting and using Small, Small Disadvantaged, and Woman-Owned Business 
Enterprises as requested by the contracting officer.
    (b) For the fiscal year [insert appropriate fiscal year], the 
Department's subcontracting goals are as follows:


Sec. (1) Goal for subcontracting to SB: ________

Sec. (2) Goal for subcontracting to SDB: ________

Sec. (3) Goal for subcontracting to SWB: ________

Sec. (4) Omnibus goals (if applicable):
    (i) 10% to minority business
    (ii) 10% to small business

                           (End of provision)

[59 FR 66768, Dec. 28, 1994]



Sec. 652.219-71  Section 8(a) Direct Awards.

    As prescribed in 619.811-3(f), insert the following clause:

                  Section 8(a) Direct Awards (AUG 1999)

    (a) This purchase order or contract is issued as a direct award 
between the contracting activity and the 8(a) contractor pursuant to the 
Memorandum of Understanding between the Small Business Administration 
(SBA) and the Department of State (DOS). SBA retains responsibility for 
8(a) certification, 8(a) eligibility determinations and related issues, 
and provides counseling and assistance to the 8(a) contractor under the 
8(a) program. The cognizant SBA district office is: [To be completed by 
the contracting officer at the time of award]
    (b) The DOS contracting officer is responsible for administering the 
purchase order or contract and taking any action on behalf of the 
Government under the terms and conditions of the purchase order or 
contract. However, the DOS contracting officer shall give advance notice 
to the SBA before it issues a final notice terminating performance, 
either in whole or in part, under the purchase order or contract. The 
DOS contracting officer

[[Page 339]]

shall also coordinate with SBA prior to processing any novation 
agreement. The DOS contracting officer may assign contract 
administration functions to a contract administration office.
    (c) The contractor agrees:
    (1) to notify the DOS contracting officer, simultaneous with its 
notification to SBA (as required by SBA's 8(a) regulations), when the 
owner or owners upon whom 8(a) eligibility is based, plan to relinquish 
ownership or control of the concern. Consistent with 15 U.S.C. 
637(a)(21), transfer of ownership or control shall result in termination 
of the contract for convenience, unless SBA waives the requirement for 
termination prior to the actual relinquishing of ownership and control; 
and,
    (2) to adhere to the requirements of FAR 52.219-14, Limitations on 
Subcontracting.

                             (End of clause)

[64 FR 43630, Aug. 11, 1999]



Sec. 652.225-70  Arab League Boycott of Israel.

    As prescribed in 625.7002(a), insert the following provision:

                Arab League Boycott of Israel (AUG 1999)

    (a) Definitions. As used in this provision:
    Foreign person means any person other than a United States person as 
defined below.
    United States person means any United States resident or national 
(other than an individual resident outside the United States and 
employed by other than a United States person), any domestic concern 
(including any permanent domestic establishment of any foreign concern), 
and any foreign subsidiary or affiliate (including any permanent foreign 
establishment) of any domestic concern which is controlled in fact by 
such domestic concern, as provided under the Export Administration Act 
of 1979, as amended.
    (b) Certification. By submitting this offer, the offeror certifies 
that it is not:
    (1) Taking or knowingly agreeing to take any action, with respect to 
the boycott of Israel by Arab League countries, which Section 8(a) of 
the Export Administration Act of 1979, as amended (50 U.S.C. 2407(a)) 
prohibits a United States person from taking; or,
    (2) Discriminating in the award of subcontracts on the basis of 
religion.

                           (End of provision)

[64 FR 43631, Aug. 11, 1999]



Sec. 652.225-71  Section 8(a) of the Export Administration Act of 1979, 
          as Amended.

    As prescribed in 625.7002(b), insert the following clause:

 Section 8(a) of the Export Administration Act of 1979, as Amended (AUG 
                                  1999)

    (a) Section 8(a) of the U.S. Export Administration Act of 1979, as 
amended (50 U.S.C. 2407(a)), prohibits compliance by U.S. persons with 
any boycott fostered by a foreign country against a country which is 
friendly to the United States and which is not itself the object of any 
form of boycott pursuant to United States law or regulation. The Boycott 
of Israel by Arab League countries is such a boycott, and therefore, the 
following actions, if taken with intent to comply with, further, or 
support the Arab League Boycott of Israel, are prohibited activities 
under the Export Administration Act:
    (1) Refusing, or requiring any U.S. person to refuse to do business 
with or in Israel, with any Israeli business concern, or with any 
national or resident of Israel, or with any other person, pursuant to an 
agreement of, or a request from or on behalf of a boycotting country;
    (2) Refusing, or requiring any U.S. person to refuse to employ or 
otherwise discriminating against any person on the basis of race, 
religion, sex, or national origin of that person or of any owner, 
officer, director, or employee of such person;
    (3) Furnishing information with respect to the race, religion, or 
national origin of any U.S. person or of any owner, officer, director, 
or employee of such U.S. person;
    (4) Furnishing information about whether any person has, has had, or 
proposes to have any business relationship (including a relationship by 
way of sale, purchase, legal or commercial representation, shipping or 
other transport, insurance, investment, or supply) with or in the State 
of Israel, with any business concern organized under the laws of the 
State of Israel, with any Israeli national or resident, or with any 
person which is known or believed to be restricted from having any 
business relationship with or in Israel;
    (5) Furnishing information about whether any person is a member of, 
has made contributions to, or is otherwise associated with or involved 
in the activities of any charitable or fraternal organization which 
supports the State of Israel; and,
    (6) Paying, honoring, confirming, or otherwise implementing a letter 
of credit which contains any condition or requirement against doing 
business with the State of Israel.
    (b) Under Section 8(a), the following types of activities are not 
forbidden ``compliance

[[Page 340]]

with the boycott,'' and are therefore exempted from Section 8(a)'s 
prohibitions listed in paragraphs (a)(1)-(6) above:
    (1) Complying or agreeing to comply with requirements:
    (i) Prohibiting the import of goods or services from Israel or goods 
produced or services provided by any business concern organized under 
the laws of Israel or by nationals or residents of Israel; or,
    (ii) Prohibiting the shipment of goods to Israel on a carrier of 
Israel, or by a route other than that prescribed by the boycotting 
country or the recipient of the shipment;
    (2) Complying or agreeing to comply with import and shipping 
document requirements with respect to the country of origin, the name of 
the carrier and route of shipment, the name of the supplier of the 
shipment or the name of the provider of other services, except that no 
information knowingly furnished or conveyed in response to such 
requirements may be stated in negative, blacklisting, or similar 
exclusionary terms, other than with respect to carriers or route of 
shipments as may be permitted by such regulations in order to comply 
with precautionary requirements protecting against war risks and 
confiscation;
    (3) Complying or agreeing to comply in the normal course of business 
with the unilateral and specific selection by a boycotting country, or 
national or resident thereof, of carriers, insurance, suppliers of 
services to be performed within the boycotting country or specific goods 
which, in the normal course of business, are identifiable by source when 
imported into the boycotting country;
    (4) Complying or agreeing to comply with the export requirements of 
the boycotting country relating to shipments or transshipments of 
exports to Israel, to any business concern of or organized under the 
laws of Israel, or to any national or resident of Israel;
    (5) Compliance by an individual or agreement by an individual to 
comply with the immigration or passport requirements of any country with 
respect to such individual or any member of such individual's family or 
with requests for information regarding requirements of employment of 
such individual within the boycotting country; and,
    (6) Compliance by a U.S. person resident in a foreign country or 
agreement by such person to comply with the laws of that country with 
respect to his or her activities exclusively therein, and such 
regulations may contain exceptions for such resident complying with the 
laws or regulations of that foreign country governing imports into such 
country of trademarked, trade named, or similarly specifically 
identifiable products, or components of products for his or her own use, 
including the performance of contractual services within that country, 
as may be defined by such regulations.

                             (End of clause)

[64 FR 43631, Aug. 11, 1999]



Sec. 652.226-70  Certification of Status as a Minority Business 
          Enterprise.

    As prescribed in 626.200-70, insert the following provision:

  Certification of Status as a Minority Business Enterprise (AUG 1999)

    The Bidder/Offeror/Supplier certifies that it [  ] is [  ] is not 
[check one] a minority business enterprise which is defined as a 
business which is at least 51 percent owned by one or more minority 
individuals or, in the case of a publicly owned business, at least 51 
percent of its voting stock is owned by one or more minority 
individuals, and whose management and daily operations are controlled by 
one or more such individuals. For purposes of this definition, minority 
individuals are:

[Check the applicable block]
    [  ] Black Americans
    [  ] Hispanic Americans
    [  ] Native Americans
    [  ] Asian-Pacific Americans
    [  ] Other groups whose members are U.S. citizens and are found to 
be disadvantaged by the Small Business Administration pursuant to 
Section 8(d) of the Small Business Act, as amended (15 U.S.C. 637(d)), 
or the Secretary of Commerce.

                           (End of provision)

    Alternate I (AUG 1999).

Certification of Status as a Minority Business Enterprise (Alternate I) 
                               (AUG 1999)

    (a) If you are a minority-owned business, please indicate in the 
comments section of your quote/response the applicable minority 
designation from those listed below. If no comments are received, it 
shall be assumed that you are not a minority-owned business. This 
request for information is to assist the Department collect statistics 
on awards to minority-owned businesses and will not influence the award 
decision.
    (b) A minority business enterprise is defined as a business which is 
at least 51 percent owned by one or more minority individuals or, in the 
case of a publicly owned business, at least 51 percent of its voting 
stock is owned by one or more minority individuals, and whose management 
and daily operations are controlled by one or more such individuals. For 
purposes of this definition, minority individuals are: Black Americans; 
Hispanic Americans; Native Americans; Asian-Pacific Americans; and, 
other groups whose members are U.S. citizens and are found to

[[Page 341]]

be disadvantaged by the Small Business Administration pursuant to 
Section 8(d) of the Small Business Act, as amended (15 U.S.C. 637(d)), 
or the Secretary of Commerce.

                           (End of provision)

[64 FR 43631, Aug. 11, 1999]



Sec. 652.228-70  Indemnification.

    As prescribed in 628.7001(b), insert the following clause:

                       Indemnification (JUL 1988)

    The Contractor expressly agrees to indemnify and to save the 
Government, its officers, agents, servants, and employees harmless from 
and against any claim, loss, damages, injury, and liability, however 
caused, resulting from or arising out of the Contractor's fault or 
negligence in connection with the performance of work under this 
contract. Further, any negligence or alleged negligence of the 
Government, its officers, agents, servants, or employees, shall not bar 
a claim for indemnification unless the act or omission of the 
Government, its officers, agents, servants, or employees is the sole 
competent, and producing cause of such claim, loss, damages, injury, or 
liability.

                             (End of clause)

[53 FR 26177, July 11, 1988, as amended at 64 FR 43632, Aug. 11, 1999]



Sec. 652.228-71  Worker's Compensation Insurance (Defense Base Act)--
          Services.

    As prescribed in 628.305(b), insert the following clause:

 Worker's Compensation Insurance (Defense Base Act)--Services (AUG 1999)

    (a) This clause supplements FAR 52.228-3.
    (b) The contractor agrees to procure Defense Base Act (DBA) 
insurance pursuant to the terms of the contract between the Department 
of State and the Department's DBA insurance carrier unless the 
contractor has a DBA self-insurance program approved by the Department 
of Labor. The contractor shall submit a copy of the Department of 
Labor's approval to the contracting officer upon contract award. The 
current rate under the Department of State contract is [contracting 
officer insert rate] of compensation for services.
    (c) Since the Department of State has obtained a waiver of DBA 
coverage for contractor employees who are not citizens of, residents of, 
or hired in the United States, the contractor agrees to provide such 
employees with worker's compensation benefits as required by the laws of 
the country in which the employees are working, or by the laws of the 
employee's native country, whichever offers greater benefits.
    (d) The contractor agrees to insert a clause substantially the same 
as this one in all subcontracts to which the DBA is applicable. 
Subcontractors shall be required to insert a similar clause in any of 
their subcontracts subject to the DBA.
    (e) Should the rates for DBA insurance coverage increase or decrease 
during the performance of this contract, the Department shall modify 
this contract accordingly.
    (f) The contractor shall demonstrate to the satisfaction of the 
contracting officer that the equitable adjustment as a result of the 
insurance increase or decrease does not include any reserve for such 
insurance. Adjustment shall not include any overhead, profit, general 
and administrative expenses, etc.

                             (End of clause)

    Alternate I (AUG 1999). If the contract is for construction, as 
prescribed in 628.305 (b), substitute the last sentence of paragraph (b) 
to read as follows:

    The current rate under the Department of State contract is 
[contracting officer insert rate] of compensation for construction.

[64 FR 43632, Aug. 11, 1999]



Sec. 652.228-72--652.228-73  [Reserved]



Sec. 652.228-74  Defense Base Act insurance rates--Limitation--Fixed-
          price.

    As prescribed in 628.306, insert the following provision:

  Defense Base Act Insurance Rates--Limitation--Fixed-Price (AUG 1999)

    (a) The Department of State has entered into a contract with an 
insurance carrier to provide DBA insurance to Department of State 
contractors at a contracted rate. The rates for this insurance are as 
follows:
    Services @ [contracting officer insert current rate] of 
compensation; or
    Construction @ [contracting officer insert current rate] of 
compensation.
    (b) Bidders/Offerors should compute the total compensation (direct 
salary plus differential, but excluding per diem, housing allowance and 
other miscellaneous post allowances) to be paid to employees who will be 
covered by DBA insurance and the cost of DBA insurance in their bid/
proposal using the foregoing rate, and insert the totals in the spaces 
provided for the base year and each year thereafter, if applicable. The 
DBA insurance cost shall be included in the total fixed price. The DBA 
insurance costs shall be reimbursed directly to the contractor.
(1) Compensation of Covered Employees:__________________________________

[[Page 342]]

_______________________________________________________________________
(2) Defense Base Act Insurance Costs:___________________________________
_______________________________________________________________________
(3) Total Cost:_________________________________________________________
    (c) Bidders/offerors shall include a statement as to whether or not 
local nationals or third country nationals will be employed on the 
resultant contract.

                           (End of provision)

[64 FR 43632, Aug. 11, 1999]



Sec. 652.228-75  [Reserved]



Sec. 652.228-76  Defense Base Act Insurance Rates--Limitation--Cost-
          Reimbursement, Labor-Hour, and Time-and-Materials.

    As prescribed in 628.307, insert the following provision:

Defense Base Act Insurance Rates--Limitation--Cost-Reimbursement, Labor-
                 Hour, and Time-and-Materials (AUG 1999)

    (a) The Department of State has entered into a contract with an 
insurance carrier to provide DBA insurance to Department of State 
contractors at a contracted rate. In preparing the cost proposal, the 
offeror shall use the following rates in computing the cost for DBA 
insurance:
    Services @ [contracting officer insert current rate] of compensation 
(direct salary plus differential, but excluding per diem, housing 
allowance, education allowance, and miscellaneous allowances); or
    Construction @ [contracting officer insert current rate] of 
compensation.
    (b) These rates apply to all job classifications in those particular 
categories. The successful offeror shall be advised of the name and 
address of the insurance broker who will process the DBA insurance 
coverage.
    (c) Should an offeror compute or include higher DBA insurance rates, 
the rates shall be disallowed.
    (d) Offerors shall include a statement as to whether or not local 
nationals or third country nationals will be employed on the resultant 
contract.

                           (End of provision)

[64 FR 43632, Aug. 11, 1999]



Sec. 652.229-70  Excise Tax Exemption Statement for Contractors Within 
          the United States.

    As prescribed in 629.401-70, insert the following clause:

Excise Tax Ememption Statement for Contractors Within the United States 
                               (JUL 1988)

    This is to certify that the item(s) covered by this contract is/are 
for export solely for the use of the U.S. Foreign Service Post 
identified in the contract schedule.
    The Contractor shall use a photocopy of this contract as evidence of 
intent to export. Final proof of exportation may be obtained from the 
agent handling the shipment. Such proof shall be accepted in lieu of 
payment of excise tax.

                             (End of clause)

[53 FR 26177, July 11, 1988, as amended at 64 FR 43632, Aug. 11, 1999]



Sec. 652.229-71  Personal Property Disposition at Posts Abroad.

    As prescribed in 629.402-1-70, insert the following clause:

        Personal Property Disposition at Posts Abroad (AUG 1999)

    Regulations at 22 CFR Part 136 require that U.S. Government 
employees and their families do not profit personally from sales or 
other transactions with persons who are not themselves entitled to 
exemption from import restrictions, duties, or taxes. Should the 
contractor experience importation or tax privileges in a foreign country 
because of its contractual relationship to the United States Government, 
the contractor shall observe the requirements of 22 CFR part 136 and all 
policies, rules, and procedures issued by the chief of mission in that 
foreign country.

                             (End of clause)

[64 FR 43633, Aug. 11, 1999]



Sec. 652.232-70  Payment Schedule and Invoice Submission (Fixed-Price).

    As prescribed in 632.908(a), the contracting officer may insert a 
clause substantially the same as follows:

    Payment Schedule and Invoice Submission (Fixed-Price) (AUG 1999)

    (a) General. The Government shall pay the contractor as full 
compensation for all work required, performed and accepted under this 
contract, inclusive of all costs and expenses, the firm fixed-price 
stated in Section B of this contract.
[Use paragraph (b) only if partial payments apply. Otherwise, paragraph 
(a) above assumes the contractor will be paid in full amount upon 
completion of all contractural requirements].

[[Page 343]]

    (b) Payment Schedule. Payments will be made in accordance with the 
following partial payment schedule:

------------------------------------------------------------------------
                                  Specific      Delivery       Payment
     Partial payment No.        deliverable       date         amount
------------------------------------------------------------------------
1                              .............  ............  ............
2                              .............  ............  ............
3                              .............  ............  ............
------------------------------------------------------------------------

[Continue as necessary]

    (c) Invoice Submission. Invoices shall be submitted in an original 
and [contracting officer insert appropriate number of copies] to the 
office identified in Block 10 of the SF-26, Block 23 of the SF-33, or 
Block 18b of the SF-1449. To constitute a proper invoice, the invoice 
must include all items per FAR 52.232-25, ``Prompt Payment''.
    (d) Contractor Remittance Address. Payment shall be made to the 
contractor's address as specified on the cover page of this contract, 
unless a separate remittance address is specified below:

_______________________________________________________________________

_______________________________________________________________________

_______________________________________________________________________

_______________________________________________________________________

                             (End of clause)

[59 FR 66771, Dec. 28, 1994, as amended at 64 FR 43633, Aug. 11, 1999]



Sec. 652.232-71  Voucher Submission (Cost-Reimbursement).

    As prescribed in 632.908(b), the contracting officer may insert a 
clause substantially the same as follows:

           Voucher Submission (Cost-Reimbursement) (AUG 1999)

    (a) General. The contractor shall submit, on a monthly basis 
[contracting officer may substitute a different time frame, if 
appropriate], an original and [contracting officer insert appropriate 
number] copies of each voucher. In addition to the items necessary per 
FAR 52.232-25, ``Prompt Payment'', the voucher shall show the elements 
of cost for the billing period and the cumulative costs to date. All 
vouchers shall be submitted to the office identified in Block 10 of the 
SF-26, Block 23 of the SF-33, or Block 18b of the SF-1449.
    (b) Contractor Remittance Address. Payment shall be made to the 
contractor's address as specified on the cover page of this contract, 
unless a separate remittance address is specified below:

_______________________________________________________________________

_______________________________________________________________________

_______________________________________________________________________

_______________________________________________________________________

                             (End of clause)

[59 FR 66772, Dec. 28, 1994, as amended at 64 FR 43633, Aug. 11, 1999]



Sec. 652.232-72  Limitation of Funds.

    As prescribed in 632.705-70, insert the following clause:

                     Limitation of Funds (AUG 1999)

    (a) Of the total price in Section B (or the ``Prices'' section), 
only the amount stated on the contract award document or subsequent 
modifications is now available for payment and obligated under this 
contract. It is anticipated that from time to time, additional funds 
will be obligated under the contract until the total price of the 
contract is obligated.
    (b) The Government is not obligated to pay or reimburse the 
contractor more than the amount obligated pursuant to this clause. The 
contractor agrees to perform the contract up to the point at which the 
total amount paid and payable by the Government (including amounts 
payable for subcontracts and settlement costs if this contract is 
terminated for convenience) approximates but does not exceed the total 
amount obligated.
    (c)(1) It is contemplated that funds now obligated under this 
contract will cover the work to be performed until [contracting officer 
insert date].
    (2) If the contractor considers the funds obligated under this 
contract to be insufficient to cover the work to be performed until that 
date, or another date agreed to by the parties, the contractor shall 
notify the contracting officer in writing and indicate the date on which 
it expects expended funds to approximate 75 percent of the total amount 
obligated. The notice shall state the estimated amount of additional 
funds required to continue performance through the date specified in 
paragraph (c)(1) of this clause or another date agreed to by the 
parties.
    (3) If, after notification is provided pursuant to paragraph (c)(2) 
of this clause, additional funds are not obligated, or an earlier date 
than the date in paragraph (c)(1) of this clause is not agreed to, the 
contractor shall not be obligated to continue performance under this 
contract (including actions under the termination clause of this 
contract) beyond the funds obligated for contract performance.
    (d) When additional funds are obligated from time to time for 
continued performance of this contract, the contract shall be modified 
to increase the funds obligated and to indicate the period of 
performance for which funds are applicable. The contractor may notify 
the contracting officer as provided in paragraph (c)(2) of this clause 
regarding any additional funds obligated.

[[Page 344]]

    (e) If the contractor incurs additional costs or is delayed in the 
performance of work under this contract, solely by reason of the 
Government's failure to obligate additional funds in amounts sufficient 
for the timely performance of this contract, an equitable adjustment may 
be made to the price, or time of delivery, or both.
    (f) This clause shall become inoperative upon obligation of funds 
sufficient to cover the full price stated in the contract, except for 
rights and obligations then existing under this clause.
    (g) Nothing in this clause shall affect the Government's right to 
terminate the contract for convenience or default.

                             (End of clause)

[64 FR 43633, Aug. 11, 1999]



Sec. 652.236-70  Accident Prevention.

    As prescribed in 636.513, insert the following clause:

                     Accident Prevention (AUG 1999)

    (a) General. The contractor shall provide and maintain work 
environments and procedures which will safeguard the public and 
Government personnel, property, materials, supplies, and equipment 
exposed to contractor operations and activities; avoid interruptions of 
Government operations and delays in project completion dates; and, 
control costs in the performance of this contract. For these purposes, 
the contractor shall:
    (1) Provide appropriate safety barricades, signs and signal lights;
    (2) Comply with the standards issued by any local government 
authority having jurisdiction over occupational health and safety 
issues; and,
    (3) Ensure that any additional measures the contracting officer 
determines to be reasonably necessary for this purpose are taken.
    (4) [The contracting officer shall specify additional requirements 
regarding safety if the work involves scaffolding or other work at 
heights above 2 meters, trenches or other excavation greater than 1 
meter, earth moving equipment, electrical hazards, work in confined 
spaces (limited exits, potential for oxygen less than 19.5%, toxic or 
combustible atmosphere, potential for solid or liquid engulfment, or 
other hazards considered to be immediately dangerous to life or health 
such as water tanks, transformer vaults, sewers, cisterns, etc.), or 
hazardous materials (especially those used indoors, e.g., paints, 
solvents, etc.).]
    (b) Records. The contractor shall maintain an accurate record of 
exposure data on all accidents incident to work performed under this 
contract resulting in death, traumatic injury, occupational disease, or 
damage to or theft of property, materials, supplies, or equipment. The 
contractor shall report this data in the manner prescribed by the 
contracting officer.
    (c) Subcontracts. The contractor shall be responsible for its 
subcontractors' compliance with this clause.
    (d) Written program. Before commencing work, the contractor shall:
    (1) Submit a written plan for implementing this clause; and,
    (2) Meet with the contracting officer to discuss and develop a 
mutual understanding relative to administration of the overall safety 
program.
    (e) Notification. The contracting officer shall notify the 
contractor of any non-compliance with these requirements and the 
corrective actions required. This notice, when delivered to the 
contractor or the contractor's representative on site, shall be deemed 
sufficient notice of the non-compliance and corrective action required. 
After receiving the notice, the contractor shall immediately take 
corrective action. If the contractor fails or refuses to promptly take 
corrective action, the contracting officer may issue an order suspending 
all or part of the work until satisfactory corrective action has been 
taken. The contractor shall not be entitled to any equitable adjustment 
of the contract price or extension of the performance schedule on any 
suspension of work order issued under this clause.

                             (End of clause)

[64 FR 43633, Aug. 11, 1999]



Sec. 652.237-70  Compensatory time off.

    As prescribed in 637.110(a), insert the following clause:

                    Compensatory Time Off (DEC 1994)

    (a) Compensatory time off means time from work during the personal 
service contract employee's basic work week in exchange for performing 
an equal amount of irregular of occasional overtime work which is 
officially ordered or approved.
    (b) At the discretion of the Contracting Officer's Representative 
(COR), the contractor may earn compensatory time off in accordance with 
3 FAM Section 232.6--Compensatory Time Off. Compensation time off 
remaining to the credit of a personal services contract employee at the 
end of a 16-week period and/or at the end of the contract period shall 
be forfeited.
    (c) Compensatory time may not be converted to overtime.


[[Page 345]]



                             (End of clause)

[59 FR 66772, Dec. 28, 1994]



Sec. 652.237-71  Identification/Building Pass.

    As prescribed in 637.110(b), insert the following clause.

                 Identification/Building Pass (AUG 1999)

    (a) The contractor shall obtain a Department of State building pass 
for all employees performing under this contract who require frequent 
and continuing access to Department of State facilities. Passes shall be 
issued only to contractor employees who are United States citizens. 
Passes will be issued by the Bureau of Diplomatic Security, Office of 
Procedural Security, Domestic Facilities Division. They shall be used 
for the purpose of contractor performance only, and shall not be used 
for any other purpose.
    (b) The contractor shall submit an application in the form 
prescribed by the COR. The contractor shall also provide a letter on 
company letterhead to accompany the application containing the following 
information:
    (1) The purpose for which the pass is being requested;
    (2) The type of access the applicant requires;
    (3) Whether or not the applicant has a valid security clearance; 
and,
    (4) The contract number and period of performance of the contract.
    (c) The complete package, including the COR's approval memorandum, 
shall be delivered to the Building Pass Application Unit, Room B266, 
Department of State, 2201 C Street, NW, Washington, DC; or, the post 
security officer, if the contract is performed at a U.S. owned or leased 
building overseas. The employee(s) for whom the pass(es) is/are being 
requested may be required to personally submit the application and to 
provide evidence of identity and United States citizenship.
    (d) All contractor employees shall wear the passes in plain sight at 
all times while in Department of State buildings. All contractor 
employees shall show their passes when entering these buildings and upon 
request.
    (e) All passes shall be returned to the COR upon separation of the 
employee, or expiration or termination of the contract. Final payment 
under this contract shall not be made until all passes are returned to 
the COR.

                             (End of clause)

[59 FR 66772, Dec. 28, 1994, as amended at 64 FR 43634, Aug. 11, 1999]



Sec. 652.237-72  Observance of Legal Holidays and Administrative Leave.

    As prescribed in 637.110(c), insert the following clause:

    Observance of Legal Holidays and Administrative Leave (AUG 1999)

    (a) The Department of State observes the following days as holidays:

New Year's Day
Martin Luther King's Birthday
Washington's Birthday
Memorial Day
Independence Day
Labor Day
Columbus Day
Veterans Day
Thanksgiving Day
Christmas Day

Any other day designated by Federal law, Executive Order, or 
Presidential Proclamation.

    (b) When any such day falls on a Saturday, the preceding Friday is 
observed; when any such day falls on a Sunday, the following Monday is 
observed. Observance of such days by Government personnel shall not be 
cause for additional period of performance or entitlement to 
compensation except as set forth in the contract. If the contractor's 
personnel work on a holiday, no form of holiday or other premium 
compensation will be reimbursed either as a direct or indirect cost, 
unless authorized pursuant to an overtime clause elsewhere in this 
contract.
    (c) When the Department of State grants administrative leave to its 
Government employees, assigned contractor personnel in Government 
facilities shall also be dismissed. However, the contractor agrees to 
continue to provide sufficient personnel to perform round-the-clock 
requirements of critical tasks already in operation or scheduled, and 
shall be guided by the instructions issued by the contracting officer or 
his/her duly authorized representative.
    (d) For fixed-price contracts, if services are not required or 
provided because the building is closed due to inclement weather, 
unanticipated holidays declared by the President, failure of Congress to 
appropriate funds, or similar reasons, deductions will be computed as 
follows:
    (1) The deduction rate in dollars per day will be equal to the per 
month contract price divided by 21 days per month.
    (2) The deduction rate in dollars per day will be multiplied by the 
number of days services are not required or provided. If services are 
provided for portions of days, appropriate adjustment will be made by 
the contracting officer to ensure that the contractor is compensated for 
services provided.

[[Page 346]]

    (e) If administrative leave is granted to contractor personnel as a 
result of conditions stipulated in any ``Excusable Delays'' clause of 
this contract, it will be without loss to the contractor. The cost of 
salaries and wages to the contractor for the period of any such excused 
absence shall be a reimbursable item of direct cost hereunder for 
employees whose regular time is normally charged, and a reimbursable 
item of indirect cost for employees whose time is normally charged 
indirectly in accordance with the contractor's accounting policy.

                             (End of clause)

[59 FR 66772, Dec. 28, 1994, as amended at 64 FR 43634, Aug. 11, 1999]



Sec. 652.242-70  Contracting Officer's Representative (COR).

    As prescribed in 642.271, insert a clause substantially the same as 
follows:

          Contracting Officer's Representative (COR) (AUG 1999)

    (a) The Contracting Officer may designate in writing one or more 
Government employees, by name and position title, to take action for the 
Contracting Officer under this contract. Each designee shall be 
identified as a Contracting Officer's Representative (COR). Such 
designation(s) shall specify the scope and limitations of the authority 
so delegated; provided, that the designee shall not change the terms or 
conditions of the contract, unless the COR is a warranted Contracting 
Officer and this authority is delegated in the designation.
    (b) The COR is [insert job title of COR].

                             (End of clause)

[53 FR 26177, July 11, 1988, as amended at 59 FR 66772, Dec. 28, 1994; 
64 FR 43634, Aug. 11, 1999]



Sec. 652.242-71  Notice of Shipments.

    As prescribed in 642.1406-2-70(a), insert the following clause:

                     Notice of Shipments (JUL 1988)

    At the time of delivery of supplies to a carrier for onward 
transportation, the Contractor shall give notice of prepaid shipment to 
the consignee establishment, and to such other persons as instructed by 
the Contracting Officer. If the Contractor has not received such 
instructions by 24 hours prior to the delivery time, the Contractor 
shall contact the Contracting Officer and request instructions from the 
Contracting Officer concerning the notice of shipment to be given.

                             (End of clause)

[53 FR 26177, July 11, 1988, as amended at 64 FR 43634, Aug. 11, 1999]



Sec. 652.242-72  Shipping Instructions.

    As prescribed in 642.1406-2-70(b), insert the following clause:

                    Shipping Instructions (DEC 1994)

    (a) Each packing box shall be of solid construction in accordance 
with best commercial practices and sufficiently strong in direct ratio 
to the weight of the contents to withstand excessively rough handling 
while in transit overseas. It shall be constructed of lumber that is 
well seasoned, reasonably sound, free from bad cross grain and from 
knots or knotholes that interfere with nailing or that occupy more than 
\1/3\ of the width of the piece of lumber. Box shall be constructed with 
three-way corners and diagonal bracing. All nails shall be cement-
coated, of correct size and properly spaced to avoid splitting or 
warping, and shall be driven into the grain of the wood. Dimension of 
lumber shall be in accordance with the following table, dependent upon 
the weight of the contents:

------------------------------------------------------------------------
                                        Minimum dimensions of lumber for
      Weight of box and contents           struts, frame members, and
                                             single diagonal braces
------------------------------------------------------------------------
Up to 45 kg...........................  19.05  x  57.15mm
46 to 113 kg..........................  22.23  x  73.03mm
114 to 181 kg.........................  22.23  x  98.43mm
182 to 272 kg.........................  22.23  x  123.83mm or 25.4  x
                                         98.43 mm
------------------------------------------------------------------------

    (b) Each box shall be lined with waterproof paper and shall be bound 
with 19.05mm" steel straps firmly stapled in position to prevent the 
straps from slipping off the box. Articles must be secured and braced 
inside the shipping container to prevent the articles from shifting.
    (c) Packing cases weighing 453.5kg and more must be equipped with 
skids. Each skid shall consist of two end sections of 50.8  x  152.4mm 
lumber placed flat and a center section of 50.8  x  101.6mm lumber 
placed flat and then arranged in line to provide 254mm forklift spaces 
between center and end sections. When goods are ready for shipment, the 
Contractor shall prepare four (4) copies of a packing list, indicating 
the contract and, if applicable, order numbers; case number; itemized 
list of contents; net and gross weights in kilograms; and outside 
dimensions, including all clears, of each shipping container. The 
Contractor shall provide three (3) copies of the packing list to the 
U.S. Despatch Agent as specified in the contract or order. The 
Contractor shall place the fourth copy of the packing list in packing 
case number one, which shall be marked

[[Page 347]]

as such so that it is easily identified by the consignee. Upon receipt 
of the packing list, the Despatch Agent will furnish export marks and 
instructions regarding shipment to the port specified, depending upon 
steamer services available at the time.
    (d) The export marks shall be stenciled on one side of each box 
reserved for that purpose, and the appropriate case number stenciled in 
the lower left-hand corner of the same side. The contract and, as 
necessary, order numbers, net and gross weights in kilograms shall be 
stenciled on the same side. However, if the size of the box is too small 
to accommodate all stenciling on one side, the contract and order 
numbers and weights may be stenciled on the side opposite that used for 
the export marks and case number.
    (e) The contract and, as necessary, order numbers must appear on all 
containers and papers relating to this clause.

                             (End of clause)

[53 FR 26177, July 11, 1988; 53 FR 36462, Sept. 20, 1988, as amended at 
59 FR 66772, Dec. 28, 1994; 64 FR 43634, Aug. 11, 1999]



Sec. 652.242-73  Authorization and Performance.

    As prescribed in 642.271(b), insert a clause substantially the same 
as follows:

                Authorization and Performance (AUG 1999)

    (a) The contractor warrants the following:
    (1) That is has obtained authorization to operate and do business in 
the country or countries in which this contract will be performed;
    (2) That is has obtained all necessary licenses and permits required 
to perform this contract; and,
    (3) That it shall comply fully with all laws, decrees, labor 
standards, and regulations of said country or countries during the 
performance of this contract.
    (b) If the party actually performing the work will be a 
subcontractor or joint venture partner, then such subcontractor or joint 
venture partner agrees to the requirements of paragraph (a) of this 
clause.

                             (End of clause)

    Alternate I (AUG 1999). If the contract is for overseas local guard 
services, as prescribed in 642.271(b), substitute the following 
paragraphs (a)(1) and (a)(2) for paragraphs (a)(1) and (a)(2) of the 
basic clause:

    (a)(1) That it has obtained authorization to operate and do business 
in the country or countries in which this contract will be performed, or 
will obtain such authorization before performance of this contract 
begins;
    (a)(2) That it has obtained all necessary licenses and permits 
required to perform this contract, or will obtain such licenses and 
permits before performance of this contract begins;

[64 FR 43634, Aug. 11, 1999]



Sec. 652.243-70  Notices.

    As prescribed in 643.104-70, insert the following clause:

                           Notices (AUG 1999)

    Any notice or request relating to this contract given by either 
party to the other shall be in writing. Said notice or request shall be 
mailed or delivered by hand to the other party at the address provided 
in the schedule of the contract. All modifications to the contract must 
be made in writing by the contracting officer.

                             (End of clause)

[64 FR 43634, Aug. 11, 1999]

                             PART 653_FORMS

Sec.

Sec. 653.000  Scope of part.

                          Subpart 653.1_General


Sec. 653.101  Requirements for use of forms.

Sec. 653.101-70  Policy.

Sec. 653.110  Continuation sheets.

                   Subpart 653.2_Prescription of Forms


Sec. 653.200  Scope of subpart.

Sec. 653.213  Simplified acquisition procedures (SF's 18, 30, 44, 1165, 
          OF's 347, 348).

Sec. 653.217  Special contracting methods.

Sec. 653.217-70  DOS form DS-1921, Award/Modification of Interagency 
          Acquisition Agreement.

Sec. 653.219  Small business programs.

Sec. 653.219-70  DOS form DS-1910, Small Business Agency Review--Actions 
          Above the Simplified Acquisition Threshold.

                  Subpart 653.3_Illustrations of Forms


Sec. 653.300  Scope of subpart.

Sec. 653.303  Agency forms.

Sec. 653.302.127  Optional Form 127, Receiving and Inspection Report.

Sec. 653.302.206  Optional Form 206, Purchase Order, Receiving Report 
          and Voucher.

Sec. 653.302.206A  Optional Form 206A, Purchase Order, Receiving Report 
          and Voucher--Continuation Sheet.

[[Page 348]]


Sec. 653.303-DS-1771  Department of State Form (DS) 1771, Contractor 
          Evaluation Statement.

Sec. 653.303-DST-1089  Department of State Form 1089, Order--Supplies or 
          Services.

    Authority: 40 U.S.C. 486(c); 22 U.S.C. 2658.

    Source: 53 FR 26180, July 11, 1988, unless otherwise noted.



Sec. 653.000  Scope of part.

    This part prescribes DOSAR forms in addition to those provided in 
FAR Part 53.

                          Subpart 653.1_General



Sec. 653.101  Requirements for use of forms.



Sec. 653.101-70  Policy.

    The forms in FAR subpart 53.2 or in subpart 653.2 shall be used as 
precribed therein, except when the use of any form is prohibited by or 
inconsistent with local laws, or the supplies or services could not be 
obtained if the form were used. The contracting officer shall justify 
the exclusion of any form in accordance with FAR subpart 1.4 and 
601.470.



Sec. 653.110  Continuation sheets.

    The provisions of FAR 53.110 also apply to forms prescribed in the 
DOSAR.

                   Subpart 653.2_Prescription of Forms



Sec. 653.200  Scope of subpart.

    This subpart prescribes or references optional and DOS forms for use 
in acquisition. Consistent with FAR 53.200, this subpart is arranged by 
subject matter, in the same order as and keyed to the parts of the DOSAR 
in which the form usage requirements are addressed.



Sec. 653.213  Simplified acquisition procedures (SF's 18, 30, 44, 1165, 
          OF's 347, 348).



Sec. 653.217  Special contracting methods.



Sec. 653.217-70  DOS form DS-1921, Award/Modification of Interagency 
          Acquisition Agreement.

    As prescribed in 617.504-70(b)(5)(i), DS-1921 is prescribed for use 
when awarding or modifying Economy Act Interagency Acquisition 
Agreements where the Department is the requesting agency.

[59 FR 66773, Dec. 28, 1994]



Sec. 653.219  Small business programs.



Sec. 653.219-70  DOS form DS-1910, Small Business Agency Review--Actions 
          Above the Simplified Acquisition Threshold.

    As prescribed in 619.501(c), DS-1910 is prescribed for use in 
documenting set-aside decisions.

[64 FR 43634, Aug. 11, 1999]

                  Subpart 653.3_Illustrations of Forms



Sec. 653.300  Scope of subpart.

    This subpart contains illustrations of forms prescribed in the DOSAR 
but not illustrated in FAR Subpart 53.3.



Sec. 653.303  Agency forms.

    This section illustrates the DOS forms that are specified by the 
DOSAR for use in acquisitions. The forms are illustrated in numerical 
order. The subsection numbers correspond with the DOS form numbers.

[[Page 349]]

[GRAPHIC] [TIFF OMITTED] TC01MR91.129


[[Page 350]]


[GRAPHIC] [TIFF OMITTED] TC01MR91.130


[[Page 351]]


[GRAPHIC] [TIFF OMITTED] TC01MR91.131


[[Page 352]]


[GRAPHIC] [TIFF OMITTED] TC01MR91.132


[[Page 353]]


[GRAPHIC] [TIFF OMITTED] TC01MR91.133


[[Page 354]]


[GRAPHIC] [TIFF OMITTED] TC01MR91.134


[[Page 355]]


[GRAPHIC] [TIFF OMITTED] TC01MR91.135


[[Page 357]]



                              FINDING AIDS




  --------------------------------------------------------------------

  A list of CFR titles, subtitles, chapters, subchapters and parts and 
an alphabetical list of agencies publishing in the CFR are included in 
the CFR Index and Finding Aids volume to the Code of Federal Regulations 
which is published separately and revised annually.

  Table of CFR Titles and Chapters
  Alphabetical List of Agencies Appearing in the CFR
  List of CFR Sections Affected



[[Page 359]]



                    Table of CFR Titles and Chapters




                     (Revised as of October 1, 2001)

                      Title 1--General Provisions

         I  Administrative Committee of the Federal Register 
                (Parts 1--49)
        II  Office of the Federal Register (Parts 50--299)
        IV  Miscellaneous Agencies (Parts 400--500)

                          Title 2--[Reserved]

                        Title 3--The President

         I  Executive Office of the President (Parts 100--199)

                           Title 4--Accounts

         I  General Accounting Office (Parts 1--99)

                   Title 5--Administrative Personnel

         I  Office of Personnel Management (Parts 1--1199)
        II  Merit Systems Protection Board (Parts 1200--1299)
       III  Office of Management and Budget (Parts 1300--1399)
         V  The International Organizations Employees Loyalty 
                Board (Parts 1500--1599)
        VI  Federal Retirement Thrift Investment Board (Parts 
                1600--1699)
       VII  Advisory Commission on Intergovernmental Relations 
                (Parts 1700--1799)
      VIII  Office of Special Counsel (Parts 1800--1899)
        IX  Appalachian Regional Commission (Parts 1900--1999)
        XI  Armed Forces Retirement Home (Part 2100)
       XIV  Federal Labor Relations Authority, General Counsel of 
                the Federal Labor Relations Authority and Federal 
                Service Impasses Panel (Parts 2400--2499)
        XV  Office of Administration, Executive Office of the 
                President (Parts 2500--2599)
       XVI  Office of Government Ethics (Parts 2600--2699)
       XXI  Department of the Treasury (Parts 3100--3199)
      XXII  Federal Deposit Insurance Corporation (Part 3201)
     XXIII  Department of Energy (Part 3301)
      XXIV  Federal Energy Regulatory Commission (Part 3401)

[[Page 360]]

       XXV  Department of the Interior (Part 3501)
      XXVI  Department of Defense (Part 3601)
    XXVIII  Department of Justice (Part 3801)
      XXIX  Federal Communications Commission (Parts 3900--3999)
       XXX  Farm Credit System Insurance Corporation (Parts 4000--
                4099)
      XXXI  Farm Credit Administration (Parts 4100--4199)
    XXXIII  Overseas Private Investment Corporation (Part 4301)
      XXXV  Office of Personnel Management (Part 4501)
        XL  Interstate Commerce Commission (Part 5001)
       XLI  Commodity Futures Trading Commission (Part 5101)
      XLII  Department of Labor (Part 5201)
     XLIII  National Science Foundation (Part 5301)
       XLV  Department of Health and Human Services (Part 5501)
      XLVI  Postal Rate Commission (Part 5601)
     XLVII  Federal Trade Commission (Part 5701)
    XLVIII  Nuclear Regulatory Commission (Part 5801)
         L  Department of Transportation (Part 6001)
       LII  Export-Import Bank of the United States (Part 6201)
      LIII  Department of Education (Parts 6300--6399)
       LIV  Environmental Protection Agency (Part 6401)
      LVII  General Services Administration (Part 6701)
     LVIII  Board of Governors of the Federal Reserve System (Part 
                6801)
       LIX  National Aeronautics and Space Administration (Part 
                6901)
        LX  United States Postal Service (Part 7001)
       LXI  National Labor Relations Board (Part 7101)
      LXII  Equal Employment Opportunity Commission (Part 7201)
     LXIII  Inter-American Foundation (Part 7301)
       LXV  Department of Housing and Urban Development (Part 
                7501)
      LXVI  National Archives and Records Administration (Part 
                7601)
      LXIX  Tennessee Valley Authority (Part 7901)
      LXXI  Consumer Product Safety Commission (Part 8101)
    LXXIII  Department of Agriculture (Part 8301)
     LXXIV  Federal Mine Safety and Health Review Commission (Part 
                8401)
     LXXVI  Federal Retirement Thrift Investment Board (Part 8601)
    LXXVII  Office of Management and Budget (Part 8701)

                          Title 6--[Reserved]

              

                         Title 7--Agriculture

            Subtitle A--Office of the Secretary of Agriculture 
                (Parts 0--26)
            Subtitle B--Regulations of the Department of 
                Agriculture

[[Page 361]]

         I  Agricultural Marketing Service (Standards, 
                Inspections, Marketing Practices), Department of 
                Agriculture (Parts 27--209)
        II  Food and Nutrition Service, Department of Agriculture 
                (Parts 210--299)
       III  Animal and Plant Health Inspection Service, Department 
                of Agriculture (Parts 300--399)
        IV  Federal Crop Insurance Corporation, Department of 
                Agriculture (Parts 400--499)
         V  Agricultural Research Service, Department of 
                Agriculture (Parts 500--599)
        VI  Natural Resources Conservation Service, Department of 
                Agriculture (Parts 600--699)
       VII  Farm Service Agency, Department of Agriculture (Parts 
                700--799)
      VIII  Grain Inspection, Packers and Stockyards 
                Administration (Federal Grain Inspection Service), 
                Department of Agriculture (Parts 800--899)
        IX  Agricultural Marketing Service (Marketing Agreements 
                and Orders; Fruits, Vegetables, Nuts), Department 
                of Agriculture (Parts 900--999)
         X  Agricultural Marketing Service (Marketing Agreements 
                and Orders; Milk), Department of Agriculture 
                (Parts 1000--1199)
        XI  Agricultural Marketing Service (Marketing Agreements 
                and Orders; Miscellaneous Commodities), Department 
                of Agriculture (Parts 1200--1299)
      XIII  Northeast Dairy Compact Commission (Parts 1300--1399)
       XIV  Commodity Credit Corporation, Department of 
                Agriculture (Parts 1400--1499)
        XV  Foreign Agricultural Service, Department of 
                Agriculture (Parts 1500--1599)
       XVI  Rural Telephone Bank, Department of Agriculture (Parts 
                1600--1699)
      XVII  Rural Utilities Service, Department of Agriculture 
                (Parts 1700--1799)
     XVIII  Rural Housing Service, Rural Business-Cooperative 
                Service, Rural Utilities Service, and Farm Service 
                Agency, Department of Agriculture (Parts 1800--
                2099)
      XXVI  Office of Inspector General, Department of Agriculture 
                (Parts 2600--2699)
     XXVII  Office of Information Resources Management, Department 
                of Agriculture (Parts 2700--2799)
    XXVIII  Office of Operations, Department of Agriculture (Parts 
                2800--2899)
      XXIX  Office of Energy, Department of Agriculture (Parts 
                2900--2999)
       XXX  Office of the Chief Financial Officer, Department of 
                Agriculture (Parts 3000--3099)
      XXXI  Office of Environmental Quality, Department of 
                Agriculture (Parts 3100--3199)
     XXXII  Office of Procurement and Property Management, 
                Department of Agriculture (Parts 3200--3299)

[[Page 362]]

    XXXIII  Office of Transportation, Department of Agriculture 
                (Parts 3300--3399)
     XXXIV  Cooperative State Research, Education, and Extension 
                Service, Department of Agriculture (Parts 3400--
                3499)
      XXXV  Rural Housing Service, Department of Agriculture 
                (Parts 3500--3599)
     XXXVI  National Agricultural Statistics Service, Department 
                of Agriculture (Parts 3600--3699)
    XXXVII  Economic Research Service, Department of Agriculture 
                (Parts 3700--3799)
   XXXVIII  World Agricultural Outlook Board, Department of 
                Agriculture (Parts 3800--3899)
       XLI  [Reserved]
      XLII  Rural Business-Cooperative Service and Rural Utilities 
                Service, Department of Agriculture (Parts 4200--
                4299)

                    Title 8--Aliens and Nationality

         I  Immigration and Naturalization Service, Department of 
                Justice (Parts 1--599)

                 Title 9--Animals and Animal Products

         I  Animal and Plant Health Inspection Service, Department 
                of Agriculture (Parts 1--199)
        II  Grain Inspection, Packers and Stockyards 
                Administration (Packers and Stockyards Programs), 
                Department of Agriculture (Parts 200--299)
       III  Food Safety and Inspection Service, Department of 
                Agriculture (Parts 300--599)

                           Title 10--Energy

         I  Nuclear Regulatory Commission (Parts 0--199)
        II  Department of Energy (Parts 200--699)
       III  Department of Energy (Parts 700--999)
         X  Department of Energy (General Provisions) (Parts 
                1000--1099)
      XVII  Defense Nuclear Facilities Safety Board (Parts 1700--
                1799)
     XVIII  Northeast Interstate Low-Level Radioactive Waste 
                Commission (Part 1800)

                      Title 11--Federal Elections

         I  Federal Election Commission (Parts 1--9099)

                      Title 12--Banks and Banking

         I  Comptroller of the Currency, Department of the 
                Treasury (Parts 1--199)

[[Page 363]]

        II  Federal Reserve System (Parts 200--299)
       III  Federal Deposit Insurance Corporation (Parts 300--399)
        IV  Export-Import Bank of the United States (Parts 400--
                499)
         V  Office of Thrift Supervision, Department of the 
                Treasury (Parts 500--599)
        VI  Farm Credit Administration (Parts 600--699)
       VII  National Credit Union Administration (Parts 700--799)
      VIII  Federal Financing Bank (Parts 800--899)
        IX  Federal Housing Finance Board (Parts 900--999)
        XI  Federal Financial Institutions Examination Council 
                (Parts 1100--1199)
       XIV  Farm Credit System Insurance Corporation (Parts 1400--
                1499)
        XV  Department of the Treasury (Parts 1500--1599)
      XVII  Office of Federal Housing Enterprise Oversight, 
                Department of Housing and Urban Development (Parts 
                1700--1799)
     XVIII  Community Development Financial Institutions Fund, 
                Department of the Treasury (Parts 1800--1899)

               Title 13--Business Credit and Assistance

         I  Small Business Administration (Parts 1--199)
       III  Economic Development Administration, Department of 
                Commerce (Parts 300--399)
        IV  Emergency Steel Guarantee Loan Board (Parts 400--499)
         V  Emergency Oil and Gas Guaranteed Loan Board (Parts 
                500--599)

                    Title 14--Aeronautics and Space

         I  Federal Aviation Administration, Department of 
                Transportation (Parts 1--199)
        II  Office of the Secretary, Department of Transportation 
                (Aviation Proceedings) (Parts 200--399)
       III  Commercial Space Transportation, Federal Aviation 
                Administration, Department of Transportation 
                (Parts 400--499)
         V  National Aeronautics and Space Administration (Parts 
                1200--1299)

                 Title 15--Commerce and Foreign Trade

            Subtitle A--Office of the Secretary of Commerce (Parts 
                0--29)
            Subtitle B--Regulations Relating to Commerce and 
                Foreign Trade
         I  Bureau of the Census, Department of Commerce (Parts 
                30--199)
        II  National Institute of Standards and Technology, 
                Department of Commerce (Parts 200--299)
       III  International Trade Administration, Department of 
                Commerce (Parts 300--399)

[[Page 364]]

        IV  Foreign-Trade Zones Board, Department of Commerce 
                (Parts 400--499)
       VII  Bureau of Export Administration, Department of 
                Commerce (Parts 700--799)
      VIII  Bureau of Economic Analysis, Department of Commerce 
                (Parts 800--899)
        IX  National Oceanic and Atmospheric Administration, 
                Department of Commerce (Parts 900--999)
        XI  Technology Administration, Department of Commerce 
                (Parts 1100--1199)
      XIII  East-West Foreign Trade Board (Parts 1300--1399)
       XIV  Minority Business Development Agency (Parts 1400--
                1499)
            Subtitle C--Regulations Relating to Foreign Trade 
                Agreements
        XX  Office of the United States Trade Representative 
                (Parts 2000--2099)
            Subtitle D--Regulations Relating to Telecommunications 
                and Information
     XXIII  National Telecommunications and Information 
                Administration, Department of Commerce (Parts 
                2300--2399)

                    Title 16--Commercial Practices

         I  Federal Trade Commission (Parts 0--999)
        II  Consumer Product Safety Commission (Parts 1000--1799)

             Title 17--Commodity and Securities Exchanges

         I  Commodity Futures Trading Commission (Parts 1--199)
        II  Securities and Exchange Commission (Parts 200--399)
        IV  Department of the Treasury (Parts 400--499)

          Title 18--Conservation of Power and Water Resources

         I  Federal Energy Regulatory Commission, Department of 
                Energy (Parts 1--399)
       III  Delaware River Basin Commission (Parts 400--499)
        VI  Water Resources Council (Parts 700--799)
      VIII  Susquehanna River Basin Commission (Parts 800--899)
      XIII  Tennessee Valley Authority (Parts 1300--1399)

                       Title 19--Customs Duties

         I  United States Customs Service, Department of the 
                Treasury (Parts 1--199)
        II  United States International Trade Commission (Parts 
                200--299)
       III  International Trade Administration, Department of 
                Commerce (Parts 300--399)

[[Page 365]]

                     Title 20--Employees' Benefits

         I  Office of Workers' Compensation Programs, Department 
                of Labor (Parts 1--199)
        II  Railroad Retirement Board (Parts 200--399)
       III  Social Security Administration (Parts 400--499)
        IV  Employees' Compensation Appeals Board, Department of 
                Labor (Parts 500--599)
         V  Employment and Training Administration, Department of 
                Labor (Parts 600--699)
        VI  Employment Standards Administration, Department of 
                Labor (Parts 700--799)
       VII  Benefits Review Board, Department of Labor (Parts 
                800--899)
      VIII  Joint Board for the Enrollment of Actuaries (Parts 
                900--999)
        IX  Office of the Assistant Secretary for Veterans' 
                Employment and Training, Department of Labor 
                (Parts 1000--1099)

                       Title 21--Food and Drugs

         I  Food and Drug Administration, Department of Health and 
                Human Services (Parts 1--1299)
        II  Drug Enforcement Administration, Department of Justice 
                (Parts 1300--1399)
       III  Office of National Drug Control Policy (Parts 1400--
                1499)

                      Title 22--Foreign Relations

         I  Department of State (Parts 1--199)
        II  Agency for International Development (Parts 200--299)
       III  Peace Corps (Parts 300--399)
        IV  International Joint Commission, United States and 
                Canada (Parts 400--499)
         V  Broadcasting Board of Governors (Parts 500--599)
       VII  Overseas Private Investment Corporation (Parts 700--
                799)
        IX  Foreign Service Grievance Board Regulations (Parts 
                900--999)
         X  Inter-American Foundation (Parts 1000--1099)
        XI  International Boundary and Water Commission, United 
                States and Mexico, United States Section (Parts 
                1100--1199)
       XII  United States International Development Cooperation 
                Agency (Parts 1200--1299)
       XIV  Foreign Service Labor Relations Board; Federal Labor 
                Relations Authority; General Counsel of the 
                Federal Labor Relations Authority; and the Foreign 
                Service Impasse Disputes Panel (Parts 1400--1499)
        XV  African Development Foundation (Parts 1500--1599)
       XVI  Japan-United States Friendship Commission (Parts 
                1600--1699)
      XVII  United States Institute of Peace (Parts 1700--1799)

[[Page 366]]

                          Title 23--Highways

         I  Federal Highway Administration, Department of 
                Transportation (Parts 1--999)
        II  National Highway Traffic Safety Administration and 
                Federal Highway Administration, Department of 
                Transportation (Parts 1200--1299)
       III  National Highway Traffic Safety Administration, 
                Department of Transportation (Parts 1300--1399)

                Title 24--Housing and Urban Development

            Subtitle A--Office of the Secretary, Department of 
                Housing and Urban Development (Parts 0--99)
            Subtitle B--Regulations Relating to Housing and Urban 
                Development
         I  Office of Assistant Secretary for Equal Opportunity, 
                Department of Housing and Urban Development (Parts 
                100--199)
        II  Office of Assistant Secretary for Housing-Federal 
                Housing Commissioner, Department of Housing and 
                Urban Development (Parts 200--299)
       III  Government National Mortgage Association, Department 
                of Housing and Urban Development (Parts 300--399)
        IV  Office of Housing and Office of Multifamily Housing 
                Assistance Restructuring, Department of Housing 
                and Urban Development (Parts 400--499)
         V  Office of Assistant Secretary for Community Planning 
                and Development, Department of Housing and Urban 
                Development (Parts 500--599)
        VI  Office of Assistant Secretary for Community Planning 
                and Development, Department of Housing and Urban 
                Development (Parts 600--699) [Reserved]
       VII  Office of the Secretary, Department of Housing and 
                Urban Development (Housing Assistance Programs and 
                Public and Indian Housing Programs) (Parts 700--
                799)
      VIII  Office of the Assistant Secretary for Housing--Federal 
                Housing Commissioner, Department of Housing and 
                Urban Development (Section 8 Housing Assistance 
                Programs, Section 202 Direct Loan Program, Section 
                202 Supportive Housing for the Elderly Program and 
                Section 811 Supportive Housing for Persons With 
                Disabilities Program) (Parts 800--899)
        IX  Office of Assistant Secretary for Public and Indian 
                Housing, Department of Housing and Urban 
                Development (Parts 900--999)
         X  Office of Assistant Secretary for Housing--Federal 
                Housing Commissioner, Department of Housing and 
                Urban Development (Interstate Land Sales 
                Registration Program) (Parts 1700--1799)
       XII  Office of Inspector General, Department of Housing and 
                Urban Development (Parts 2000--2099)
        XX  Office of Assistant Secretary for Housing--Federal 
                Housing Commissioner, Department of Housing and 
                Urban Development (Parts 3200--3899)
       XXV  Neighborhood Reinvestment Corporation (Parts 4100--
                4199)

[[Page 367]]

                           Title 25--Indians

         I  Bureau of Indian Affairs, Department of the Interior 
                (Parts 1--299)
        II  Indian Arts and Crafts Board, Department of the 
                Interior (Parts 300--399)
       III  National Indian Gaming Commission, Department of the 
                Interior (Parts 500--599)
        IV  Office of Navajo and Hopi Indian Relocation (Parts 
                700--799)
         V  Bureau of Indian Affairs, Department of the Interior, 
                and Indian Health Service, Department of Health 
                and Human Services (Part 900)
        VI  Office of the Assistant Secretary-Indian Affairs, 
                Department of the Interior (Parts 1000--1199)
       VII  Office of the Special Trustee for American Indians, 
                Department of the Interior (Part 1200)

                      Title 26--Internal Revenue

         I  Internal Revenue Service, Department of the Treasury 
                (Parts 1--899)

           Title 27--Alcohol, Tobacco Products and Firearms

         I  Bureau of Alcohol, Tobacco and Firearms, Department of 
                the Treasury (Parts 1--299)

                   Title 28--Judicial Administration

         I  Department of Justice (Parts 0--199)
       III  Federal Prison Industries, Inc., Department of Justice 
                (Parts 300--399)
         V  Bureau of Prisons, Department of Justice (Parts 500--
                599)
        VI  Offices of Independent Counsel, Department of Justice 
                (Parts 600--699)
       VII  Office of Independent Counsel (Parts 700--799)
      VIII  Court Services and Offender Supervision Agency for the 
                District of Columbia (Parts 800--899)
        IX  National Crime Prevention and Privacy Compact Council 
                (Parts 900--999)
        XI  Department of Justice and Department of State (Parts 
                1100--1199)

                            Title 29--Labor

            Subtitle A--Office of the Secretary of Labor (Parts 
                0--99)
            Subtitle B--Regulations Relating to Labor
         I  National Labor Relations Board (Parts 100--199)
        II  Office of Labor-Management Standards, Department of 
                Labor (Parts 200--299)
       III  National Railroad Adjustment Board (Parts 300--399)

[[Page 368]]

        IV  Office of Labor-Management Standards, Department of 
                Labor (Parts 400--499)
         V  Wage and Hour Division, Department of Labor (Parts 
                500--899)
        IX  Construction Industry Collective Bargaining Commission 
                (Parts 900--999)
         X  National Mediation Board (Parts 1200--1299)
       XII  Federal Mediation and Conciliation Service (Parts 
                1400--1499)
       XIV  Equal Employment Opportunity Commission (Parts 1600--
                1699)
      XVII  Occupational Safety and Health Administration, 
                Department of Labor (Parts 1900--1999)
        XX  Occupational Safety and Health Review Commission 
                (Parts 2200--2499)
       XXV  Pension and Welfare Benefits Administration, 
                Department of Labor (Parts 2500--2599)
     XXVII  Federal Mine Safety and Health Review Commission 
                (Parts 2700--2799)
        XL  Pension Benefit Guaranty Corporation (Parts 4000--
                4999)

                      Title 30--Mineral Resources

         I  Mine Safety and Health Administration, Department of 
                Labor (Parts 1--199)
        II  Minerals Management Service, Department of the 
                Interior (Parts 200--299)
       III  Board of Surface Mining and Reclamation Appeals, 
                Department of the Interior (Parts 300--399)
        IV  Geological Survey, Department of the Interior (Parts 
                400--499)
        VI  Bureau of Mines, Department of the Interior (Parts 
                600--699)
       VII  Office of Surface Mining Reclamation and Enforcement, 
                Department of the Interior (Parts 700--999)

                 Title 31--Money and Finance: Treasury

            Subtitle A--Office of the Secretary of the Treasury 
                (Parts 0--50)
            Subtitle B--Regulations Relating to Money and Finance
         I  Monetary Offices, Department of the Treasury (Parts 
                51--199)
        II  Fiscal Service, Department of the Treasury (Parts 
                200--399)
        IV  Secret Service, Department of the Treasury (Parts 
                400--499)
         V  Office of Foreign Assets Control, Department of the 
                Treasury (Parts 500--599)
        VI  Bureau of Engraving and Printing, Department of the 
                Treasury (Parts 600--699)
       VII  Federal Law Enforcement Training Center, Department of 
                the Treasury (Parts 700--799)
      VIII  Office of International Investment, Department of the 
                Treasury (Parts 800--899)
        IX  Federal Claims Collection Standards (Department of the 
                Treasury--Department of Justice) (Parts 900--999)

[[Page 369]]

                      Title 32--National Defense

            Subtitle A--Department of Defense
         I  Office of the Secretary of Defense (Parts 1--399)
         V  Department of the Army (Parts 400--699)
        VI  Department of the Navy (Parts 700--799)
       VII  Department of the Air Force (Parts 800--1099)
            Subtitle B--Other Regulations Relating to National 
                Defense
       XII  Defense Logistics Agency (Parts 1200--1299)
       XVI  Selective Service System (Parts 1600--1699)
     XVIII  National Counterintelligence Center (Parts 1800--1899)
       XIX  Central Intelligence Agency (Parts 1900--1999)
        XX  Information Security Oversight Office, National 
                Archives and Records Administration (Parts 2000--
                2099)
       XXI  National Security Council (Parts 2100--2199)
      XXIV  Office of Science and Technology Policy (Parts 2400--
                2499)
     XXVII  Office for Micronesian Status Negotiations (Parts 
                2700--2799)
    XXVIII  Office of the Vice President of the United States 
                (Parts 2800--2899)

               Title 33--Navigation and Navigable Waters

         I  Coast Guard, Department of Transportation (Parts 1--
                199)
        II  Corps of Engineers, Department of the Army (Parts 
                200--399)
        IV  Saint Lawrence Seaway Development Corporation, 
                Department of Transportation (Parts 400--499)

                          Title 34--Education

            Subtitle A--Office of the Secretary, Department of 
                Education (Parts 1--99)
            Subtitle B--Regulations of the Offices of the 
                Department of Education
         I  Office for Civil Rights, Department of Education 
                (Parts 100--199)
        II  Office of Elementary and Secondary Education, 
                Department of Education (Parts 200--299)
       III  Office of Special Education and Rehabilitative 
                Services, Department of Education (Parts 300--399)
        IV  Office of Vocational and Adult Education, Department 
                of Education (Parts 400--499)
         V  Office of Bilingual Education and Minority Languages 
                Affairs, Department of Education (Parts 500--599)
        VI  Office of Postsecondary Education, Department of 
                Education (Parts 600--699)
       VII  Office of Educational Research and Improvement, 
                Department of Education (Parts 700--799)
        XI  National Institute for Literacy (Parts 1100--1199)
            Subtitle C--Regulations Relating to Education
       XII  National Council on Disability (Parts 1200--1299)

[[Page 370]]

                        Title 35--Panama Canal

         I  Panama Canal Regulations (Parts 1--299)

             Title 36--Parks, Forests, and Public Property

         I  National Park Service, Department of the Interior 
                (Parts 1--199)
        II  Forest Service, Department of Agriculture (Parts 200--
                299)
       III  Corps of Engineers, Department of the Army (Parts 
                300--399)
        IV  American Battle Monuments Commission (Parts 400--499)
         V  Smithsonian Institution (Parts 500--599)
       VII  Library of Congress (Parts 700--799)
      VIII  Advisory Council on Historic Preservation (Parts 800--
                899)
        IX  Pennsylvania Avenue Development Corporation (Parts 
                900--999)
         X  Presidio Trust (Parts 1000--1099)
        XI  Architectural and Transportation Barriers Compliance 
                Board (Parts 1100--1199)
       XII  National Archives and Records Administration (Parts 
                1200--1299)
        XV  Oklahoma City National Memorial Trust (Part 1501)
       XVI  Morris K. Udall Scholarship and Excellence in National 
                Environmental Policy Foundation (Parts 1600--1699)

             Title 37--Patents, Trademarks, and Copyrights

         I  United States Patent and Trademark Office, Department 
                of Commerce (Parts 1--199)
        II  Copyright Office, Library of Congress (Parts 200--299)
        IV  Assistant Secretary for Technology Policy, Department 
                of Commerce (Parts 400--499)
         V  Under Secretary for Technology, Department of Commerce 
                (Parts 500--599)

           Title 38--Pensions, Bonuses, and Veterans' Relief

         I  Department of Veterans Affairs (Parts 0--99)

                       Title 39--Postal Service

         I  United States Postal Service (Parts 1--999)
       III  Postal Rate Commission (Parts 3000--3099)

                  Title 40--Protection of Environment

         I  Environmental Protection Agency (Parts 1--799)
        IV  Environmental Protection Agency and Department of 
                Justice (Parts 1400--1499)
         V  Council on Environmental Quality (Parts 1500--1599)
        VI  Chemical Safety and Hazard Investigation Board (Parts 
                1600--1699)

[[Page 371]]

       VII  Environmental Protection Agency and Department of 
                Defense; Uniform National Discharge Standards for 
                Vessels of the Armed Forces (Parts 1700--1799)

          Title 41--Public Contracts and Property Management

            Subtitle B--Other Provisions Relating to Public 
                Contracts
        50  Public Contracts, Department of Labor (Parts 50-1--50-
                999)
        51  Committee for Purchase From People Who Are Blind or 
                Severely Disabled (Parts 51-1--51-99)
        60  Office of Federal Contract Compliance Programs, Equal 
                Employment Opportunity, Department of Labor (Parts 
                60-1--60-999)
        61  Office of the Assistant Secretary for Veterans 
                Employment and Training, Department of Labor 
                (Parts 61-1--61-999)
            Subtitle C--Federal Property Management Regulations 
                System
       101  Federal Property Management Regulations (Parts 101-1--
                101-99)
       102  Federal Management Regulation (Parts 102-1--102-299)
       105  General Services Administration (Parts 105-1--105-999)
       109  Department of Energy Property Management Regulations 
                (Parts 109-1--109-99)
       114  Department of the Interior (Parts 114-1--114-99)
       115  Environmental Protection Agency (Parts 115-1--115-99)
       128  Department of Justice (Parts 128-1--128-99)
            Subtitle D--Other Provisions Relating to Property 
                Management [Reserved]
            Subtitle E--Federal Information Resources Management 
                Regulations System
       201  Federal Information Resources Management Regulation 
                (Parts 201-1--201-99) [Reserved]
            Subtitle F--Federal Travel Regulation System
       300  General (Parts 300-1--300-99)
       301  Temporary Duty (TDY) Travel Allowances (Parts 301-1--
                301-99)
       302  Relocation Allowances (Parts 302-1--302-99)
       303  Payment of Expenses Connected with the Death of 
                Certain Employees (Part 303-70)
       304  Payment from a Non-Federal Source for Travel Expenses 
                (Parts 304-1--304-99)

                        Title 42--Public Health

         I  Public Health Service, Department of Health and Human 
                Services (Parts 1--199)
        IV  Centers for Medicare & Medicaid Services, Department 
                of Health and Human Services (Parts 400--499)
         V  Office of Inspector General-Health Care, Department of 
                Health and Human Services (Parts 1000--1999)

[[Page 372]]

                   Title 43--Public Lands: Interior

            Subtitle A--Office of the Secretary of the Interior 
                (Parts 1--199)
            Subtitle B--Regulations Relating to Public Lands
         I  Bureau of Reclamation, Department of the Interior 
                (Parts 200--499)
        II  Bureau of Land Management, Department of the Interior 
                (Parts 1000--9999)
       III  Utah Reclamation Mitigation and Conservation 
                Commission (Parts 10000--10005)

             Title 44--Emergency Management and Assistance

         I  Federal Emergency Management Agency (Parts 0--399)
        IV  Department of Commerce and Department of 
                Transportation (Parts 400--499)

                       Title 45--Public Welfare

            Subtitle A--Department of Health and Human Services 
                (Parts 1--199)
            Subtitle B--Regulations Relating to Public Welfare
        II  Office of Family Assistance (Assistance Programs), 
                Administration for Children and Families, 
                Department of Health and Human Services (Parts 
                200--299)
       III  Office of Child Support Enforcement (Child Support 
                Enforcement Program), Administration for Children 
                and Families, Department of Health and Human 
                Services (Parts 300--399)
        IV  Office of Refugee Resettlement, Administration for 
                Children and Families Department of Health and 
                Human Services (Parts 400--499)
         V  Foreign Claims Settlement Commission of the United 
                States, Department of Justice (Parts 500--599)
        VI  National Science Foundation (Parts 600--699)
       VII  Commission on Civil Rights (Parts 700--799)
      VIII  Office of Personnel Management (Parts 800--899)
         X  Office of Community Services, Administration for 
                Children and Families, Department of Health and 
                Human Services (Parts 1000--1099)
        XI  National Foundation on the Arts and the Humanities 
                (Parts 1100--1199)
       XII  Corporation for National and Community Service (Parts 
                1200--1299)
      XIII  Office of Human Development Services, Department of 
                Health and Human Services (Parts 1300--1399)
       XVI  Legal Services Corporation (Parts 1600--1699)
      XVII  National Commission on Libraries and Information 
                Science (Parts 1700--1799)
     XVIII  Harry S. Truman Scholarship Foundation (Parts 1800--
                1899)
       XXI  Commission on Fine Arts (Parts 2100--2199)

[[Page 373]]

     XXIII  Arctic Research Commission (Part 2301)
      XXIV  James Madison Memorial Fellowship Foundation (Parts 
                2400--2499)
       XXV  Corporation for National and Community Service (Parts 
                2500--2599)

                          Title 46--Shipping

         I  Coast Guard, Department of Transportation (Parts 1--
                199)
        II  Maritime Administration, Department of Transportation 
                (Parts 200--399)
       III  Coast Guard (Great Lakes Pilotage), Department of 
                Transportation (Parts 400--499)
        IV  Federal Maritime Commission (Parts 500--599)

                      Title 47--Telecommunication

         I  Federal Communications Commission (Parts 0--199)
        II  Office of Science and Technology Policy and National 
                Security Council (Parts 200--299)
       III  National Telecommunications and Information 
                Administration, Department of Commerce (Parts 
                300--399)

           Title 48--Federal Acquisition Regulations System

         1  Federal Acquisition Regulation (Parts 1--99)
         2  Department of Defense (Parts 200--299)
         3  Department of Health and Human Services (Parts 300--
                399)
         4  Department of Agriculture (Parts 400--499)
         5  General Services Administration (Parts 500--599)
         6  Department of State (Parts 600--699)
         7  United States Agency for International Development 
                (Parts 700--799)
         8  Department of Veterans Affairs (Parts 800--899)
         9  Department of Energy (Parts 900--999)
        10  Department of the Treasury (Parts 1000--1099)
        12  Department of Transportation (Parts 1200--1299)
        13  Department of Commerce (Parts 1300--1399)
        14  Department of the Interior (Parts 1400--1499)
        15  Environmental Protection Agency (Parts 1500--1599)
        16  Office of Personnel Management Federal Employees 
                Health Benefits Acquisition Regulation (Parts 
                1600--1699)
        17  Office of Personnel Management (Parts 1700--1799)
        18  National Aeronautics and Space Administration (Parts 
                1800--1899)
        19  Broadcasting Board of Governors (Parts 1900--1999)
        20  Nuclear Regulatory Commission (Parts 2000--2099)

[[Page 374]]

        21  Office of Personnel Management, Federal Employees 
                Group Life Insurance Federal Acquisition 
                Regulation (Parts 2100--2199)
        23  Social Security Administration (Parts 2300--2399)
        24  Department of Housing and Urban Development (Parts 
                2400--2499)
        25  National Science Foundation (Parts 2500--2599)
        28  Department of Justice (Parts 2800--2899)
        29  Department of Labor (Parts 2900--2999)
        34  Department of Education Acquisition Regulation (Parts 
                3400--3499)
        35  Panama Canal Commission (Parts 3500--3599)
        44  Federal Emergency Management Agency (Parts 4400--4499)
        51  Department of the Army Acquisition Regulations (Parts 
                5100--5199)
        52  Department of the Navy Acquisition Regulations (Parts 
                5200--5299)
        53  Department of the Air Force Federal Acquisition 
                Regulation Supplement (Parts 5300--5399)
        54  Defense Logistics Agency, Department of Defense (Part 
                5452)
        57  African Development Foundation (Parts 5700--5799)
        61  General Services Administration Board of Contract 
                Appeals (Parts 6100--6199)
        63  Department of Transportation Board of Contract Appeals 
                (Parts 6300--6399)
        99  Cost Accounting Standards Board, Office of Federal 
                Procurement Policy, Office of Management and 
                Budget (Parts 9900--9999)

                       Title 49--Transportation

            Subtitle A--Office of the Secretary of Transportation 
                (Parts 1--99)
            Subtitle B--Other Regulations Relating to 
                Transportation
         I  Research and Special Programs Administration, 
                Department of Transportation (Parts 100--199)
        II  Federal Railroad Administration, Department of 
                Transportation (Parts 200--299)
       III  Federal Motor Carrier Safety Administration, 
                Department of Transportation (Parts 300--399)
        IV  Coast Guard, Department of Transportation (Parts 400--
                499)
         V  National Highway Traffic Safety Administration, 
                Department of Transportation (Parts 500--599)
        VI  Federal Transit Administration, Department of 
                Transportation (Parts 600--699)
       VII  National Railroad Passenger Corporation (AMTRAK) 
                (Parts 700--799)
      VIII  National Transportation Safety Board (Parts 800--999)
         X  Surface Transportation Board, Department of 
                Transportation (Parts 1000--1399)

[[Page 375]]

        XI  Bureau of Transportation Statistics, Department of 
                Transportation (Parts 1400--1499)

                   Title 50--Wildlife and Fisheries

         I  United States Fish and Wildlife Service, Department of 
                the Interior (Parts 1--199)
        II  National Marine Fisheries Service, National Oceanic 
                and Atmospheric Administration, Department of 
                Commerce (Parts 200--299)
       III  International Fishing and Related Activities (Parts 
                300--399)
        IV  Joint Regulations (United States Fish and Wildlife 
                Service, Department of the Interior and National 
                Marine Fisheries Service, National Oceanic and 
                Atmospheric Administration, Department of 
                Commerce); Endangered Species Committee 
                Regulations (Parts 400--499)
         V  Marine Mammal Commission (Parts 500--599)
        VI  Fishery Conservation and Management, National Oceanic 
                and Atmospheric Administration, Department of 
                Commerce (Parts 600--699)

                      CFR Index and Finding Aids

            Subject/Agency Index
            List of Agency Prepared Indexes
            Parallel Tables of Statutory Authorities and Rules
            List of CFR Titles, Chapters, Subchapters, and Parts
            Alphabetical List of Agencies Appearing in the CFR



[[Page 377]]





           Alphabetical List of Agencies Appearing in the CFR




                     (Revised as of October 1, 2001)

                                                  CFR Title, Subtitle or 
                     Agency                               Chapter

Administrative Committee of the Federal Register  1, I
Advanced Research Projects Agency                 32, I
Advisory Commission on Intergovernmental          5, VII
     Relations
Advisory Council on Historic Preservation         36, VIII
African Development Foundation                    22, XV
  Federal Acquisition Regulation                  48, 57
Agency for International Development, United      22, II
     States
  Federal Acquisition Regulation                  48, 7
Agricultural Marketing Service                    7, I, IX, X, XI
Agricultural Research Service                     7, V
Agriculture Department                            5, LXXIII
  Agricultural Marketing Service                  7, I, IX, X, XI
  Agricultural Research Service                   7, V
  Animal and Plant Health Inspection Service      7, III; 9, I
  Chief Financial Officer, Office of              7, XXX
  Commodity Credit Corporation                    7, XIV
  Cooperative State Research, Education, and      7, XXXIV
       Extension Service
  Economic Research Service                       7, XXXVII
  Energy, Office of                               7, XXIX
  Environmental Quality, Office of                7, XXXI
  Farm Service Agency                             7, VII, XVIII
  Federal Acquisition Regulation                  48, 4
  Federal Crop Insurance Corporation              7, IV
  Food and Nutrition Service                      7, II
  Food Safety and Inspection Service              9, III
  Foreign Agricultural Service                    7, XV
  Forest Service                                  36, II
  Grain Inspection, Packers and Stockyards        7, VIII; 9, II
       Administration
  Information Resources Management, Office of     7, XXVII
  Inspector General, Office of                    7, XXVI
  National Agricultural Library                   7, XLI
  National Agricultural Statistics Service        7, XXXVI
  Natural Resources Conservation Service          7, VI
  Operations, Office of                           7, XXVIII
  Procurement and Property Management, Office of  7, XXXII
  Rural Business-Cooperative Service              7, XVIII, XLII
  Rural Development Administration                7, XLII
  Rural Housing Service                           7, XVIII, XXXV
  Rural Telephone Bank                            7, XVI
  Rural Utilities Service                         7, XVII, XVIII, XLII
  Secretary of Agriculture, Office of             7, Subtitle A
  Transportation, Office of                       7, XXXIII
  World Agricultural Outlook Board                7, XXXVIII
Air Force Department                              32, VII
  Federal Acquisition Regulation Supplement       48, 53
Alcohol, Tobacco and Firearms, Bureau of          27, I
AMTRAK                                            49, VII
American Battle Monuments Commission              36, IV
American Indians, Office of the Special Trustee   25, VII
Animal and Plant Health Inspection Service        7, III; 9, I
Appalachian Regional Commission                   5, IX
Architectural and Transportation Barriers         36, XI
   Compliance Board
[[Page 378]]

Arctic Research Commission                        45, XXIII
Armed Forces Retirement Home                      5, XI
Army Department                                   32, V
  Engineers, Corps of                             33, II; 36, III
  Federal Acquisition Regulation                  48, 51
Benefits Review Board                             20, VII
Bilingual Education and Minority Languages        34, V
     Affairs, Office of
Blind or Severely Disabled, Committee for         41, 51
     Purchase From People Who Are
Broadcasting Board of Governors                   22, V
  Federal Acquisition Regulation                  48, 19
Census Bureau                                     15, I
Central Intelligence Agency                       32, XIX
Chief Financial Officer, Office of                7, XXX
Child Support Enforcement, Office of              45, III
Children and Families, Administration for         45, II, III, IV, X
Civil Rights, Commission on                       45, VII
Civil Rights, Office for                          34, I
Coast Guard                                       33, I; 46, I; 49, IV
Coast Guard (Great Lakes Pilotage)                46, III
Commerce Department                               44, IV
  Census Bureau                                   15, I
  Economic Affairs, Under Secretary               37, V
  Economic Analysis, Bureau of                    15, VIII
  Economic Development Administration             13, III
  Emergency Management and Assistance             44, IV
  Export Administration, Bureau of                15, VII
  Federal Acquisition Regulation                  48, 13
  Fishery Conservation and Management             50, VI
  Foreign-Trade Zones Board                       15, IV
  International Trade Administration              15, III; 19, III
  National Institute of Standards and Technology  15, II
  National Marine Fisheries Service               50, II, IV, VI
  National Oceanic and Atmospheric                15, IX; 50, II, III, IV, 
       Administration                             VI
  National Telecommunications and Information     15, XXIII; 47, III
       Administration
  National Weather Service                        15, IX
  Patent and Trademark Office, United States      37, I
  Productivity, Technology and Innovation,        37, IV
       Assistant Secretary for
  Secretary of Commerce, Office of                15, Subtitle A
  Technology, Under Secretary for                 37, V
  Technology Administration                       15, XI
  Technology Policy, Assistant Secretary for      37, IV
Commercial Space Transportation                   14, III
Commodity Credit Corporation                      7, XIV
Commodity Futures Trading Commission              5, XLI; 17, I
Community Planning and Development, Office of     24, V, VI
     Assistant Secretary for
Community Services, Office of                     45, X
Comptroller of the Currency                       12, I
Construction Industry Collective Bargaining       29, IX
     Commission
Consumer Product Safety Commission                5, LXXI; 16, II
Cooperative State Research, Education, and        7, XXXIV
     Extension Service
Copyright Office                                  37, II
Corporation for National and Community Service    45, XII, XXV
Cost Accounting Standards Board                   48, 99
Council on Environmental Quality                  40, V
Court Services and Offender Supervision Agency    28, VIII
     for the District of Columbia
Customs Service, United States                    19, I
Defense Contract Audit Agency                     32, I
Defense Department                                5, XXVI; 32, Subtitle A; 
                                                  40, VII
  Advanced Research Projects Agency               32, I
  Air Force Department                            32, VII

[[Page 379]]

  Army Department                                 32, V; 33, II; 36, III, 
                                                  48, 51
  Defense Intelligence Agency                     32, I
  Defense Logistics Agency                        32, I, XII; 48, 54
  Engineers, Corps of                             33, II; 36, III
  Federal Acquisition Regulation                  48, 2
  National Imagery and Mapping Agency             32, I
  Navy Department                                 32, VI; 48, 52
  Secretary of Defense, Office of                 32, I
Defense Contract Audit Agency                     32, I
Defense Intelligence Agency                       32, I
Defense Logistics Agency                          32, XII; 48, 54
Defense Nuclear Facilities Safety Board           10, XVII
Delaware River Basin Commission                   18, III
District of Columbia, Court Services and          28, VIII
     Offender Supervision Agency for the
Drug Enforcement Administration                   21, II
East-West Foreign Trade Board                     15, XIII
Economic Affairs, Under Secretary                 37, V
Economic Analysis, Bureau of                      15, VIII
Economic Development Administration               13, III
Economic Research Service                         7, XXXVII
Education, Department of                          5, LIII
  Bilingual Education and Minority Languages      34, V
       Affairs, Office of
  Civil Rights, Office for                        34, I
  Educational Research and Improvement, Office    34, VII
       of
  Elementary and Secondary Education, Office of   34, II
  Federal Acquisition Regulation                  48, 34
  Postsecondary Education, Office of              34, VI
  Secretary of Education, Office of               34, Subtitle A
  Special Education and Rehabilitative Services,  34, III
       Office of
  Vocational and Adult Education, Office of       34, IV
Educational Research and Improvement, Office of   34, VII
Elementary and Secondary Education, Office of     34, II
Emergency Oil and Gas Guaranteed Loan Board       13, V
Emergency Steel Guarantee Loan Board              13, IV
Employees' Compensation Appeals Board             20, IV
Employees Loyalty Board                           5, V
Employment and Training Administration            20, V
Employment Standards Administration               20, VI
Endangered Species Committee                      50, IV
Energy, Department of                             5, XXIII; 10, II, III, X
  Federal Acquisition Regulation                  48, 9
  Federal Energy Regulatory Commission            5, XXIV; 18, I
  Property Management Regulations                 41, 109
Energy, Office of                                 7, XXIX
Engineers, Corps of                               33, II; 36, III
Engraving and Printing, Bureau of                 31, VI
Environmental Protection Agency                   5, LIV; 40, I, IV, VII
  Federal Acquisition Regulation                  48, 15
  Property Management Regulations                 41, 115
Environmental Quality, Office of                  7, XXXI
Equal Employment Opportunity Commission           5, LXII; 29, XIV
Equal Opportunity, Office of Assistant Secretary  24, I
     for
Executive Office of the President                 3, I
  Administration, Office of                       5, XV
  Environmental Quality, Council on               40, V
  Management and Budget, Office of                25, III, LXXVII; 48, 99
  National Drug Control Policy, Office of         21, III
  National Security Council                       32, XXI; 47, 2
  Presidential Documents                          3
  Science and Technology Policy, Office of        32, XXIV; 47, II
  Trade Representative, Office of the United      15, XX
       States
Export Administration, Bureau of                  15, VII
Export-Import Bank of the United States           5, LII; 12, IV
Family Assistance, Office of                      45, II

[[Page 380]]

Farm Credit Administration                        5, XXXI; 12, VI
Farm Credit System Insurance Corporation          5, XXX; 12, XIV
Farm Service Agency                               7, VII, XVIII
Federal Acquisition Regulation                    48, 1
Federal Aviation Administration                   14, I
  Commercial Space Transportation                 14, III
Federal Claims Collection Standards               31, IX
Federal Communications Commission                 5, XXIX; 47, I
Federal Contract Compliance Programs, Office of   41, 60
Federal Crop Insurance Corporation                7, IV
Federal Deposit Insurance Corporation             5, XXII; 12, III
Federal Election Commission                       11, I
Federal Emergency Management Agency               44, I
  Federal Acquisition Regulation                  48, 44
Federal Employees Group Life Insurance Federal    48, 21
     Acquisition Regulation
Federal Employees Health Benefits Acquisition     48, 16
     Regulation
Federal Energy Regulatory Commission              5, XXIV; 18, I
Federal Financial Institutions Examination        12, XI
     Council
Federal Financing Bank                            12, VIII
Federal Highway Administration                    23, I, II
Federal Home Loan Mortgage Corporation            1, IV
Federal Housing Enterprise Oversight Office       12, XVII
Federal Housing Finance Board                     12, IX
Federal Labor Relations Authority, and General    5, XIV; 22, XIV
     Counsel of the Federal Labor Relations 
     Authority
Federal Law Enforcement Training Center           31, VII
Federal Management Regulation                     41, 102
Federal Maritime Commission                       46, IV
Federal Mediation and Conciliation Service        29, XII
Federal Mine Safety and Health Review Commission  5, LXXIV; 29, XXVII
Federal Motor Carrier Safety Administration       49, III
Federal Prison Industries, Inc.                   28, III
Federal Procurement Policy Office                 48, 99
Federal Property Management Regulations           41, 101
Federal Railroad Administration                   49, II
Federal Register, Administrative Committee of     1, I
Federal Register, Office of                       1, II
Federal Reserve System                            12, II
  Board of Governors                              5, LVIII
Federal Retirement Thrift Investment Board        5, VI, LXXVI
Federal Service Impasses Panel                    5, XIV
Federal Trade Commission                          5, XLVII; 16, I
Federal Transit Administration                    49, VI
Federal Travel Regulation System                  41, Subtitle F
Fine Arts, Commission on                          45, XXI
Fiscal Service                                    31, II
Fish and Wildlife Service, United States          50, I, IV
Fishery Conservation and Management               50, VI
Food and Drug Administration                      21, I
Food and Nutrition Service                        7, II
Food Safety and Inspection Service                9, III
Foreign Agricultural Service                      7, XV
Foreign Assets Control, Office of                 31, V
Foreign Claims Settlement Commission of the       45, V
     United States
Foreign Service Grievance Board                   22, IX
Foreign Service Impasse Disputes Panel            22, XIV
Foreign Service Labor Relations Board             22, XIV
Foreign-Trade Zones Board                         15, IV
Forest Service                                    36, II
General Accounting Office                         4, I
General Services Administration                   5, LVII; 41, 105
  Contract Appeals, Board of                      48, 61
  Federal Acquisition Regulation                  48, 5
  Federal Management Regulation                   41, 102
  Federal Property Management Regulation          41, 101
  Federal Travel Regulation System                41, Subtitle F

[[Page 381]]

  General                                         41, 300
  Payment From a Non-Federal Source for Travel    41, 304
       Expenses
  Payment of Expenses Connected With the Death    41, 303
       of Certain Employees
  Relocation Allowances                           41, 302
  Temporary Duty (TDY) Travel Allowances          41, 301
Geological Survey                                 30, IV
Government Ethics, Office of                      5, XVI
Government National Mortgage Association          24, III
Grain Inspection, Packers and Stockyards          7, VIII; 9, II
     Administration
Harry S. Truman Scholarship Foundation            45, XVIII
Health and Human Services, Department of          5, XLV; 45, Subtitle A
  Child Support Enforcement, Office of            45, III
  Children and Families, Administration for       45, II, III, IV, X
  Community Services, Office of                   45, X
  Family Assistance, Office of                    45, II
  Federal Acquisition Regulation                  48, 3
  Food and Drug Administration                    21, I
  Centers for Medicare & Medicaid Services        42, IV
  Human Development Services, Office of           45, XIII
  Indian Health Service                           25, V
  Inspector General (Health Care), Office of      42, V
  Public Health Service                           42, I
  Refugee Resettlement, Office of                 45, IV
Centers for Medicare & Medicaid Services          42, IV
Housing and Urban Development, Department of      5, LXV; 24, Subtitle B
  Community Planning and Development, Office of   24, V, VI
       Assistant Secretary for
  Equal Opportunity, Office of Assistant          24, I
       Secretary for
  Federal Acquisition Regulation                  48, 24
  Federal Housing Enterprise Oversight, Office    12, XVII
       of
  Government National Mortgage Association        24, III
  Housing--Federal Housing Commissioner, Office   24, II, VIII, X, XX
       of Assistant Secretary for
  Housing, Office of, and Multifamily Housing     24, IV
       Assistance Restructuring, Office of
  Inspector General, Office of                    24, XII
  Public and Indian Housing, Office of Assistant  24, IX
       Secretary for
  Secretary, Office of                            24, Subtitle A, VII
Housing--Federal Housing Commissioner, Office of  24, II, VIII, X, XX
     Assistant Secretary for
Housing, Office of, and Multifamily Housing       24, IV
     Assistance Restructuring, Office of
Human Development Services, Office of             45, XIII
Immigration and Naturalization Service            8, I
Independent Counsel, Office of                    28, VII
Indian Affairs, Bureau of                         25, I, V
Indian Affairs, Office of the Assistant           25, VI
     Secretary
Indian Arts and Crafts Board                      25, II
Indian Health Service                             25, V
Information Resources Management, Office of       7, XXVII
Information Security Oversight Office, National   32, XX
     Archives and Records Administration
Inspector General
  Agriculture Department                          7, XXVI
  Health and Human Services Department            42, V
  Housing and Urban Development Department        24, XII
Institute of Peace, United States                 22, XVII
Inter-American Foundation                         5, LXIII; 22, X
Intergovernmental Relations, Advisory Commission  5, VII
     on
Interior Department
  American Indians, Office of the Special         25, VII
       Trustee
  Endangered Species Committee                    50, IV
  Federal Acquisition Regulation                  48, 14
  Federal Property Management Regulations System  41, 114
  Fish and Wildlife Service, United States        50, I, IV
  Geological Survey                               30, IV

[[Page 382]]

  Indian Affairs, Bureau of                       25, I, V
  Indian Affairs, Office of the Assistant         25, VI
       Secretary
  Indian Arts and Crafts Board                    25, II
  Land Management, Bureau of                      43, II
  Minerals Management Service                     30, II
  Mines, Bureau of                                30, VI
  National Indian Gaming Commission               25, III
  National Park Service                           36, I
  Reclamation, Bureau of                          43, I
  Secretary of the Interior, Office of            43, Subtitle A
  Surface Mining and Reclamation Appeals, Board   30, III
       of
  Surface Mining Reclamation and Enforcement,     30, VII
       Office of
Internal Revenue Service                          26, I
International Boundary and Water Commission,      22, XI
     United States and Mexico, United States 
     Section
International Development, United States Agency   22, II
     for
  Federal Acquisition Regulation                  48, 7
International Development Cooperation Agency,     22, XII
     United States
International Fishing and Related Activities      50, III
International Investment, Office of               31, VIII
International Joint Commission, United States     22, IV
     and Canada
International Organizations Employees Loyalty     5, V
     Board
International Trade Administration                15, III; 19, III
International Trade Commission, United States     19, II
Interstate Commerce Commission                    5, XL
James Madison Memorial Fellowship Foundation      45, XXIV
Japan-United States Friendship Commission         22, XVI
Joint Board for the Enrollment of Actuaries       20, VIII
Justice Department                                5, XXVIII; 28, I, XI; 40, 
                                                  IV
  Drug Enforcement Administration                 21, II
  Federal Acquisition Regulation                  48, 28
  Federal Claims Collection Standards             31, IX
  Federal Prison Industries, Inc.                 28, III
  Foreign Claims Settlement Commission of the     45, V
       United States
  Immigration and Naturalization Service          8, I
  Offices of Independent Counsel                  28, VI
  Prisons, Bureau of                              28, V
  Property Management Regulations                 41, 128
Labor Department                                  5, XLII
  Benefits Review Board                           20, VII
  Employees' Compensation Appeals Board           20, IV
  Employment and Training Administration          20, V
  Employment Standards Administration             20, VI
  Federal Acquisition Regulation                  48, 29
  Federal Contract Compliance Programs, Office    41, 60
       of
  Federal Procurement Regulations System          41, 50
  Labor-Management Standards, Office of           29, II, IV
  Mine Safety and Health Administration           30, I
  Occupational Safety and Health Administration   29, XVII
  Pension and Welfare Benefits Administration     29, XXV
  Public Contracts                                41, 50
  Secretary of Labor, Office of                   29, Subtitle A
  Veterans' Employment and Training, Office of    41, 61; 20, IX
       the Assistant Secretary for
  Wage and Hour Division                          29, V
  Workers' Compensation Programs, Office of       20, I
Labor-Management Standards, Office of             29, II, IV
Land Management, Bureau of                        43, II
Legal Services Corporation                        45, XVI
Library of Congress                               36, VII
  Copyright Office                                37, II
Management and Budget, Office of                  5, III, LXXVII; 48, 99
Marine Mammal Commission                          50, V
Maritime Administration                           46, II

[[Page 383]]

Merit Systems Protection Board                    5, II
Micronesian Status Negotiations, Office for       32, XXVII
Mine Safety and Health Administration             30, I
Minerals Management Service                       30, II
Mines, Bureau of                                  30, VI
Minority Business Development Agency              15, XIV
Miscellaneous Agencies                            1, IV
Monetary Offices                                  31, I
Morris K. Udall Scholarship and Excellence in     36, XVI
     National Environmental Policy Foundation
National Aeronautics and Space Administration     5, LIX; 14, V
  Federal Acquisition Regulation                  48, 18
National Agricultural Library                     7, XLI
National Agricultural Statistics Service          7, XXXVI
National and Community Service, Corporation for   45, XII, XXV
National Archives and Records Administration      5, LXVI; 36, XII
  Information Security Oversight Office           32, XX
National Bureau of Standards                      15, II
National Capital Planning Commission              1, IV
National Commission for Employment Policy         1, IV
National Commission on Libraries and Information  45, XVII
     Science
National Council on Disability                    34, XII
National Counterintelligence Center               32, XVIII
National Credit Union Administration              12, VII
National Crime Prevention and Privacy Compact     28, IX
     Council
National Drug Control Policy, Office of           21, III
National Foundation on the Arts and the           45, XI
     Humanities
National Highway Traffic Safety Administration    23, II, III; 49, V
National Imagery and Mapping Agency               32, I
National Indian Gaming Commission                 25, III
National Institute for Literacy                   34, XI
National Institute of Standards and Technology    15, II
National Labor Relations Board                    5, LXI; 29, I
National Marine Fisheries Service                 50, II, IV, VI
National Mediation Board                          29, X
National Oceanic and Atmospheric Administration   15, IX; 50, II, III, IV, 
                                                  VI
National Park Service                             36, I
National Railroad Adjustment Board                29, III
National Railroad Passenger Corporation (AMTRAK)  49, VII
National Science Foundation                       5, XLIII; 45, VI
  Federal Acquisition Regulation                  48, 25
National Security Council                         32, XXI
National Security Council and Office of Science   47, II
     and Technology Policy
National Telecommunications and Information       15, XXIII; 47, III
     Administration
National Transportation Safety Board              49, VIII
National Weather Service                          15, IX
Natural Resources Conservation Service            7, VI
Navajo and Hopi Indian Relocation, Office of      25, IV
Navy Department                                   32, VI
  Federal Acquisition Regulation                  48, 52
Neighborhood Reinvestment Corporation             24, XXV
Northeast Dairy Compact Commission                7, XIII
Northeast Interstate Low-Level Radioactive Waste  10, XVIII
     Commission
Nuclear Regulatory Commission                     5, XLVIII; 10, I
  Federal Acquisition Regulation                  48, 20
Occupational Safety and Health Administration     29, XVII
Occupational Safety and Health Review Commission  29, XX
Offices of Independent Counsel                    28, VI
Oklahoma City National Memorial Trust             36, XV
Operations Office                                 7, XXVIII
Overseas Private Investment Corporation           5, XXXIII; 22, VII
Panama Canal Commission                           48, 35
Panama Canal Regulations                          35, I
Patent and Trademark Office, United States        37, I

[[Page 384]]

Payment From a Non-Federal Source for Travel      41, 304
     Expenses
Payment of Expenses Connected With the Death of   41, 303
     Certain Employees
Peace Corps                                       22, III
Pennsylvania Avenue Development Corporation       36, IX
Pension and Welfare Benefits Administration       29, XXV
Pension Benefit Guaranty Corporation              29, XL
Personnel Management, Office of                   5, I, XXXV; 45, VIII
  Federal Acquisition Regulation                  48, 17
  Federal Employees Group Life Insurance Federal  48, 21
       Acquisition Regulation
  Federal Employees Health Benefits Acquisition   48, 16
       Regulation
Postal Rate Commission                            5, XLVI; 39, III
Postal Service, United States                     5, LX; 39, I
Postsecondary Education, Office of                34, VI
President's Commission on White House             1, IV
     Fellowships
Presidential Documents                            3
Presidio Trust                                    36, X
Prisons, Bureau of                                28, V
Procurement and Property Management, Office of    7, XXXII
Productivity, Technology and Innovation,          37, IV
     Assistant Secretary
Public Contracts, Department of Labor             41, 50
Public and Indian Housing, Office of Assistant    24, IX
     Secretary for
Public Health Service                             42, I
Railroad Retirement Board                         20, II
Reclamation, Bureau of                            43, I
Refugee Resettlement, Office of                   45, IV
Regional Action Planning Commissions              13, V
Relocation Allowances                             41, 302
Research and Special Programs Administration      49, I
Rural Business-Cooperative Service                7, XVIII, XLII
Rural Development Administration                  7, XLII
Rural Housing Service                             7, XVIII, XXXV
Rural Telephone Bank                              7, XVI
Rural Utilities Service                           7, XVII, XVIII, XLII
Saint Lawrence Seaway Development Corporation     33, IV
Science and Technology Policy, Office of          32, XXIV
Science and Technology Policy, Office of, and     47, II
     National Security Council
Secret Service                                    31, IV
Securities and Exchange Commission                17, II
Selective Service System                          32, XVI
Small Business Administration                     13, I
Smithsonian Institution                           36, V
Social Security Administration                    20, III; 48, 23
Soldiers' and Airmen's Home, United States        5, XI
Special Counsel, Office of                        5, VIII
Special Education and Rehabilitative Services,    34, III
     Office of
State Department                                  22, I; 28, XI
  Federal Acquisition Regulation                  48, 6
Surface Mining and Reclamation Appeals, Board of  30, III
Surface Mining Reclamation and Enforcement,       30, VII
     Office of
Surface Transportation Board                      49, X
Susquehanna River Basin Commission                18, VIII
Technology Administration                         15, XI
Technology Policy, Assistant Secretary for        37, IV
Technology, Under Secretary for                   37, V
Tennessee Valley Authority                        5, LXIX; 18, XIII
Thrift Supervision Office, Department of the      12, V
     Treasury
Trade Representative, United States, Office of    15, XX
Transportation, Department of                     5, L
  Coast Guard                                     33, I; 46, I; 49, IV
  Coast Guard (Great Lakes Pilotage)              46, III
  Commercial Space Transportation                 14, III
  Contract Appeals, Board of                      48, 63
  Emergency Management and Assistance             44, IV

[[Page 385]]

  Federal Acquisition Regulation                  48, 12
  Federal Aviation Administration                 14, I
  Federal Highway Administration                  23, I, II
  Federal Motor Carrier Safety Administration     49, III
  Federal Railroad Administration                 49, II
  Federal Transit Administration                  49, VI
  Maritime Administration                         46, II
  National Highway Traffic Safety Administration  23, II, III; 49, V
  Research and Special Programs Administration    49, I
  Saint Lawrence Seaway Development Corporation   33, IV
  Secretary of Transportation, Office of          14, II; 49, Subtitle A
  Surface Transportation Board                    49, X
  Transportation Statistics Bureau                49, XI
Transportation, Office of                         7, XXXIII
Transportation Statistics Brureau                 49, XI
Travel Allowances, Temporary Duty (TDY)           41, 301
Treasury Department                               5, XXI; 12, XV; 17, IV; 
                                                  31, IX
  Alcohol, Tobacco and Firearms, Bureau of        27, I
  Community Development Financial Institutions    12, XVIII
       Fund
  Comptroller of the Currency                     12, I
  Customs Service, United States                  19, I
  Engraving and Printing, Bureau of               31, VI
  Federal Acquisition Regulation                  48, 10
  Federal Law Enforcement Training Center         31, VII
  Fiscal Service                                  31, II
  Foreign Assets Control, Office of               31, V
  Internal Revenue Service                        26, I
  International Investment, Office of             31, VIII
  Monetary Offices                                31, I
  Secret Service                                  31, IV
  Secretary of the Treasury, Office of            31, Subtitle A
  Thrift Supervision, Office of                   12, V
Truman, Harry S. Scholarship Foundation           45, XVIII
United States and Canada, International Joint     22, IV
     Commission
United States and Mexico, International Boundary  22, XI
     and Water Commission, United States Section
Utah Reclamation Mitigation and Conservation      43, III
     Commission
Veterans Affairs Department                       38, I
  Federal Acquisition Regulation                  48, 8
Veterans' Employment and Training, Office of the  41, 61; 20, IX
     Assistant Secretary for
Vice President of the United States, Office of    32, XXVIII
Vocational and Adult Education, Office of         34, IV
Wage and Hour Division                            29, V
Water Resources Council                           18, VI
Workers' Compensation Programs, Office of         20, I
World Agricultural Outlook Board                  7, XXXVIII

[[Page 387]]



List of CFR Sections Affected



All changes in this volume of the Code of Federal Regulations which were 
made by documents published in the Federal Register since January 1, 
1986, are enumerated in the following list. Entries indicate the nature 
of the changes effected. Page numbers refer to Federal Register pages. 
The user should consult the entries for chapters and parts as well as 
sections for revisions.
For the period before January 1, 1986, see the ``List of CFR Sections 
Affected, 1973-1985,'' published in four separate volumes.

                                  1986

48 CFR
                                                                   51 FR
                                                                    Page
Chapter 3
301.105  Amended...................................................44293
301.670-3  (a) amended.............................................44293
302.100  Amended...................................................23231
    Amended........................................................44293
    Technical correction...........................................47353
303.704 (Subpart 303.7)  Added.....................................44293
304.601  Redesignated as 304.602...................................44293
304.602  Redesignated from 304.601.................................44293
304.7101  (c) amended..............................................44293
305  Subchapter assignment; editorial note..........................6004
305.202 (Subpart 305.2)  Added.....................................44293
306  Subchapter assignment; editorial note..........................6004
306.202  (a) revised; (b) amended..................................44293
306.302-1  Heading revised; (b)(2) and (6) redesignated as 
        (a)(2)(ii) and (b)(4); new (a) heading revised; new (b) 
        heading added..............................................44293
307.104  (c) revised...............................................44293
313.404  Removed...................................................44293
314.404  Added.....................................................44294
314.404-1  Added...................................................44294
315.103 (Subpart 315.1)  Added.....................................44294
315.413-2  (e) and (f) amended.....................................44294
315.608  (b) amended...............................................44294
315.804  Added.....................................................44294
315.804-3  Added...................................................44294
316.301-3  (c) introductory text amended...........................44294
316.306  Added.....................................................44294
316.403 (Subpart 316.4)  Added.....................................44294
316.603-3  Amended.................................................44294
319.870  (a)(1) and (6) amended....................................44294
322  Added.........................................................44294
322.604-2  Heading correctly added.................................47353
325.102  (b) revised...............................................44294
    (b) correctly designated.......................................47353
330.304 (Subpart 330.3)  Added.....................................44294
332.402  Revised...................................................44294
332.406  (c)(2) amended............................................44294
332.407  (d) amended...............................................44294
332.409-1  Amended.................................................44294
332.501--332.501-2 (Subpart 332.5)  Added..........................44294
353.370-393  Added.................................................44295
Chapter 3, Appendix A
PHS 301.105  Table revised (OMB numbers)...........................20486
PHS 301.207  Heading, (a), and (b) amended.........................20486
PHS 301.470  (b) introductory text amended; (b)(1), (2) and (5) 
        removed; (b)(3) and (4) redesignated as (b)(1) and (2).....20486
PHS 304.670-1  Amended.............................................20486
PHS 304.7101  (b)(2)(i) and (c) table revised; (b)(2)(iii) added 
                                                                   20486
PHS 305  Added.....................................................20487
PHS 306  Added.....................................................20487
PHS 314.406-3  (g)(3) revised......................................20488
PHS 314.406-4  (e)(2) revised......................................20488
PHS 314.407-8  Removed.............................................20488
PHS 314.470  Removed...............................................20488
PHS 315  Removed...................................................20488
    Added; interim.................................................43357
    Effective date corrected.......................................45229
PHS 315.412  (c)(1) corrected......................................45229
PHS 323  Added.....................................................20488
PHS 333  Added.....................................................20488
PHS 335  Added.....................................................20489

[[Page 388]]

PHS 336  Added.....................................................20489
PHS 352.215-10  Added; interim.....................................43357
    Text and effective date corrected..............................45229
PHS 352.223-70  Added..............................................20489
PHS 352.223-71  Added..............................................20490
PHS 352.232-70  Added..............................................20490
PHS 352.280-1  Revised.............................................20490
PHS 352.280-2  Revised.............................................20491
PHS 352.280-4  (a) amended.........................................20491
PHS 380.101--PHS 380.105 (Subpart PHS 380.1)  Revised..............20491
PHS 380.201--PHS 380.206 (Subpart PHS 380.2)  Revised..............20492
Chapter 4
401.601  (a)(9) and (c) removed; (a)(10) redesignated as (a)(9)....34564
401.602-1  Removed.................................................34564
401.603-1  Revised.................................................34564
401.671--401.671-5  Added..........................................34565
401.7001--401.7006 (Subpart 401.70)  Added.........................34565
405--410 (Subchapter B)  Heading revised...........................34566
405  Subchapter assignment; editorial note..........................6004
    Transferred to Subchapter B....................................34566
406  Added.........................................................34566
413.505-70  (b) revised............................................34566
414  Heading revised...............................................34566
414.404-1  Added...................................................34566
414.407-8  Removed.................................................34566
415.103  Added.....................................................34566
415.307 (Subpart 415.3)  Removed...................................34566
422.1003--422.1011 (Subpart 422.10)  Removed.......................34566
433  Revised.......................................................34566
433.003  Correctly redesignated as 433.203 and (a) amended.........41790
433.003-70  Correctly redesignated as 433.203-70...................41790
433.009  Correctly redesignated as 433.209 and amended.............41790
433.011  Correctly redesignated as 433.211 and amended.............41790
433.012  Correctly redesignated as 433.212.........................41790
433.203--433.212  Correctly redesignated as Subpart 433.2..........41790
433.203  Correctly redesignated from 433.003 and (a) amended.......41790
433.203-70  Correctly redesignated from 433.003-70.................41790
433.209  Correctly redesignated from 433.009 and amended...........41790
433.211  Correctly redesignated from 433.011 and amended...........41790
433.212  Correctly redesignated from 433.012.......................41790
436.370 (Subpart 436.3)  Heading revised...........................34567
Chapter 5
501.602-1  Revised.................................................45892
501.603  (a), (b)(1) and (2)(i) and (ii), and (c)(2), (4), and (6) 
        revised; (b)(2)(viii) removed; (b)(2)(ix) through (xiii) 
        redesignated as (b)(2)(viii) through (xii).................45892
501.603-1  Revised.................................................45893
501.603-2  (c)(1), (3) introductory text, (ii)(E), and (v)(C), 
        (4), and (5) introductory text revised; (c)(3)(ii)(F) 
        through (K) and (6) redesignated as (c)(3)(ii)(G) through 
        (L) and (7) and revised; (c)(3)(ii)(F), (v)(D), and (6) 
        added......................................................16690
    (c)(3) introductory text corrected.............................21175
    (c) revised; (d) added.........................................45893
501.603-3  (a) revised.............................................16691
501.704-70  (e) added...............................................5332
501.707  Introductory text and Table 501-1 amended..................5332
501.770  Introductory text amended; (a) through (c), (e) through 
        (g), and (i) through (k) revised............................5332
502.101  Revised...................................................39861
504.7001  Revised..................................................16691
504.7001-1  (b) revised............................................16691
504.7001-2  (c) and (f) amended....................................16691
504.7001-3  Introductory text, (a), and (e) introductory text 
        revised....................................................16691
505  Subchapter assignment; editorial note..........................6004
505.101  See Appendix C Temp. Reg. AC-86-7.........................41507
505.201  See Appendix C Temp. Reg. AC-86-7.........................41507
506  Subchapter assignment; editorial note..........................6004
506.302-1  Revised.................................................44990
506.302-5  Removed.................................................44991
506.303-1  Revised.................................................44991
506.303-2  Revised.................................................44991
506.304  Revised...................................................44991
508.602  (b) revised...............................................24668

[[Page 389]]

508.705-70  (b) revised............................................24668
508.705-73  Temp. Reg. AC-86-3......................................8678
    (a) introductory text and (1) revised..........................24668
509.105-1  (d) revised.............................................39862
    (a) and (c) revised............................................45896
509.106-70  Revised................................................39862
509.406-3  (b)(3) revised..........................................39862
510.011  (c) revised; (d) removed..................................23061
510.070-1  Revised.................................................23061
513  See Temp. Reg. AC-86-4, Supp. 1...............................36700
513.105  See Appendix C Temp. Reg. AC-86-7.........................41507
513.203-1  Revised.................................................45893
    (b) revised....................................................45896
513.403  Revised...................................................45894
513.404  Added.....................................................45894
    Temp. Reg. AC-86-1..............................................1814
513.405  Added.....................................................45894
513.501  Revised...................................................45894
513.505-2  (a) and (b) revised.....................................45894
      Temp. Reg. AC-86-4...........................................12704
513.505-3  (b) revised.............................................45894
513.7001  Temp. Reg. AC-86-1........................................1814
    (a), (b)(1), and (g) revised; (d)(2) and (3) redesignated as 
(d)(3) and (4); new (d)(2) added...................................45894
    Temp. Reg. AC-86-4.............................................12704
514.205-1  (a) revised.............................................16691
514.211  Added.....................................................16692
514.270-1  Revised.................................................45897
514.270-2  (b), (c)(1)(ii) and (2) introductory text, (iv), and 
        (v) revised................................................45897
514.403  Revised...................................................45896
514.407-3  Revised.................................................23061
514.408-1  Added...................................................16692
515.605  Removed...................................................23061
515.605-70  Removed................................................23061
515.608  Revised...................................................23061
515.608-70  Added..................................................23061
515.608-71  Added..................................................23061
515.803  Revised...................................................16692
515.805-5  Revised.................................................16692
516.603-3  Revised.................................................39862
519.501  See Appendix C Temp. Reg. AC-86-7.........................41507
519.502-1  See Appendix C Temp. Reg. AC-86-7.......................41507
Chapter 5  Appendix C Temporary Reg. AC-86-7 added.................41507
519.505  See Appendix C Temp. Reg. AC-86-7.........................41508
519.508  See Appendix C Temp. Reg. AC-86-7.........................41508
522.301  Temp. Reg. AC-86-2.........................................4367
522.302  Temp. Reg. AC-86-2.........................................4367
    Heading revised................................................32655
522.305  Temp. Reg. AC-86-2.........................................4367
522.402-3  Temp. Reg. AC-86-2.......................................4367
    Revised........................................................32655
522.403  (a) amended; (c) revised..................................32655
522.404-1  (a) revised.............................................32655
522.404-4  (a), (b) introductory text, (c) and (d) revised.........32655
522.602  Temp. Reg. AC-86-2.........................................4368
522.1005  Revised..................................................28815
522.1006  Revised..................................................28815
522.1007  Revised..................................................28816
522.1008  Revised..................................................28816
525.105-70  Temp. Reg. AC-86-5.....................................16693
525.105-71  Temp. Reg. AC-86-5.....................................16693
525.402  (a) revised...............................................24668
525.402-71  (c) revised............................................24668
528.106-6  Revised.................................................23061
532.111  (a) revised...............................................23061
    (b), (c), (d) (1) and (2), and (e) introductory text and (1) 
revised; (f) and (g) added.........................................23063
    (b)(2) and (f) corrected.......................................26251
533.104  (a)(3) (v) and (vi), (4), (b), and (c) revised; (a)(5) 
        amended; (d) added..........................................5333
533.105  (a)(1) introductory text and (ii), (b) introductory text, 
        (c), and (d)(3) revised; (a)(1)(iii) amended................5334
536.302-70  (c) introductory text, (1) and (2) revised..............5334
536.303  Revised....................................................5334
536.303-70  Revised.................................................5334
546.301  Added......................................................8679
546.302  Amended....................................................8679
546.302-70  Revised.................................................8679
546.302-71  Revised.................................................8679
546.302-72  Revised.................................................8679
546.400  Revised...................................................35221
546.402  Revised...................................................35221
546.403  Revised...................................................35221
546.407  Removed...................................................35221
546.470  Revised...................................................35221
546.470-1  Revised.................................................35221
546.470-2  (b) revised.............................................35221
549.502--549.570 (Subpart 549.5)  Added..............................195
552.210-71  Amended................................................23061
552.210-72  Revised................................................23062
552.210-73  Revised................................................23062
552.210-74  Introductory text revised..............................23062
552.212-72  (a) and (b) amended....................................45895

[[Page 390]]

552.214-16  Added..................................................45898
552.219-4  See Appendix C Temp. Reg. AC-86-7.......................41508
552.219-71  Revised................................................28816
552.222-43  Revised................................................28816
552.222-71  Temp. Reg. AC-86-2......................................4368
    Removed........................................................32656
552.222-84  Revised................................................28817
552.222-85  Introductory text revised..............................28817
552.222-86  Introductory text revised..............................28818
552.225-71  Temp. Reg. AC-86-5.....................................16693
552.232-8  Revised.................................................23062
552.232-23  Revised................................................23062
552.232-70  See Temp. Reg. AC-85-1, Supp. 2.........................5335
    (a) and (b) revised; (c) through (f) removed; (g) redesignated 
as (c) and introductory text revised...............................23063
552.232-71  Revised................................................23064
552.232-72  Introductory text revised..............................23064
552.232-78  Added..................................................23064
552.232-79  Added..................................................23065
552.246-70  Introductory text revised...............................8679
552.246-71  Introductory text revised...............................8679
552.246-72  Introductory text revised...............................8679
552.246-73  Amended.................................................8679
552.246-74  Amended.................................................8680
552.246-75  Amended.................................................8680
552.246-76  Revised.................................................8680
552.246-77  Added...................................................8680
552.247-70  Introductory text revised................................195
552.249-70  Added....................................................195
552.249-71  Added....................................................196
552.249-72  Added....................................................196
553  See Temp. Reg. AC-86-4, Supp. 1...............................36700
    (c) table amended..............................................45896
553.173  (c) table amended...................................8681, 16692
553.270-3  Temp. Reg. AC-86-2.......................................4368
    (a), (b), (c), and (e) revised.................................32656
    (b) revised....................................................45895
553.272  Temp. Reg. AC-86-4........................................12705
    (a), (b), and (d) revised......................................45895
553.273  Temp. Reg. AC-86-4........................................12705
    Revised.................................................45895, 45896
553.275  (a) revised...............................................45895
553.370-300-I  Temp. Reg. AC-86-4..................................12705
553.370-3539  Added.................................................8680
Chapter 5  Temporary Reg. AC-86-1 added.............................1814
    Temporary Reg. AC-86-2 added....................................4367
    Temporary Reg. AC-85-1, Supp. 2 added...........................5335
    Temporary Reg. AC-86-3 added....................................8678
    Temporary Reg. AC-86-4 added...................................12704
    Temporary Reg. AC-86-4 technical correction....................16175
    Temporary Reg. AC-85-5 added...................................16693
    Temporary Reg. AC-86-1, Supp. 1 added..........................25703
    Temporary Reg. AC-86-6 added...................................25703
    Temporary Reg. AC-86-4, Supp. 1 added..........................36700

                                  1987

48 CFR
                                                                   52 FR
                                                                    Page
Chapter 3
301.670-2  (b) revised.............................................27558
302.100  Amended...................................................27558
304.7101  (c) amended..............................................27558
306.501  Amended...................................................27558
319.801--319.870 (Subpart 319.8)  Revised..........................27558
332.402  Revised...................................................27560
332.407  (d) amended...............................................27560
332.409-1  Amended.................................................27560
332.501-2  (a)(3) amended..........................................27560
352.227-1  Removed.................................................27560
Chapter 3, Appendix A
PHS 315.412  Addition confirmed; (c)(1) amended....................44397
PHS 352.215-10  Addition confirmed.................................44397
PHS 352.280-1  (b) amended..........................................9300
PHS 352.280-2  (b) amended..........................................9300
Chapter 5
503.303 (Subpart 503.3)  Heading revised............................5982
503.700--503.705 (Subpart 503.7)  Added.............................5982
505.101  Revised...................................................22655
505.201  Revised...................................................22655
505.202  (c) added.................................................22655
505.203  Added.....................................................22655
505.207  (b) revised...............................................22655

[[Page 391]]

507.305  Temporary Reg. AC-87-1 added...............................8590
    Revised........................................................28827
    Temporary Reg. AC-87-1, Supp. 1 added..........................35093
507.306  Temporary Reg. AC-87-1 added...............................8590
    Temporary Reg. AC-87-1, Supp. 1 added..........................35093
507.307  Revised...................................................28827
508.802  Revised...................................................28827
508.870  Removed...................................................28827
509.403  (a) revised...............................................22656
509.404  Revised...................................................22656
509.405  Revised...................................................22656
514.201-6  (b) removed..............................................6562
514.201-71  (b) revised.............................................6562
515.407  (b) removed................................................6562
515.411-70  Revised.................................................6563
519.001  Added.....................................................16390
519.201  Removed...................................................16391
519.202  (a), (b), (c), and (e) revised............................16391
519.202-5  Revised.................................................16391
519.302  Revised...................................................16391
519.304  Added.....................................................16391
519.501  Removed...................................................16391
519.502-1  (a), (b), (c), (d), (f), (g), (h), (i) and (j) revised 
                                                                   16391
519.502-2  Removed.................................................16392
519.502-3  Revised.................................................16392
519.502-70  Added..................................................16392
519.503  Revised...................................................16392
519.505  Removed...................................................16393
519.506  Removed...................................................16393
519.602--519.602-1  Added..........................................16393
519.602-3  Added...................................................16393
519.705  Added.....................................................34388
519.705-4  Added...................................................34388
519.705-5  Added...................................................34388
519.705-6  Revised.................................................34388
519.706-70  Temporary Reg. AC-87-3 added...........................47396
519.770  Added.....................................................34389
519.770-1  Added...................................................34389
519.770-2  Added...................................................34389
519.770-3  Temporary Reg. AC-87-3 added............................47397
522.1308  Temporary Reg. AC-87-2 added.............................12182
    Temporary Reg. AC-87-2, Supp. 1 added..........................37618
522.1370  Temporary Reg. AC-87-2 added.............................12182
    Temporary Reg. AC-87-2, Supp. 1 added..........................37618
525.105-70  Heading, (b), (c), and (d) revised.......................278
525.105-71  Revised..................................................279
525.105-72  (b) and (c) revised......................................279
525.108-70  (a) introductory text, (b) introductory text, and (c) 
        revised......................................................279
525.402  Temporary Reg. AC-86-8 added.................................58
    Temporary Reg. AC-86-8, Supp. 1 added..........................28828
528.102-1  (a) revised..............................................6564
528.301  Revised....................................................6564
532.111  (a)(1) revised............................................47006
533.102  (b) revised................................................6563
533.105  (a)(1)(ii), (3) and (4) and (b) introductory text and (3) 
        revised.....................................................6563
537.201  Revised....................................................6563
537.205  Revised....................................................6563
542.1107  (a) revised..............................................21057
542.7000--542.7002-3 (Subpart 542.70)  Added.......................11826
552.203-70  Amended................................................28827
552.207-70  Introductory text revised..............................28827
552.207-71  Temporary Reg. AC-87-1 added............................8590
    Temporary Reg. AC-87-1, Supp. 1 added..........................35093
552.214-71  Introductory text revised...............................6563
552.214-72  Removed.................................................6563
552.214-73  Introductory text revised...............................6563
552.214-74  Introductory text revised...............................6563
552.214-75  Introductory text revised...............................6564
552.215-71  Introductory text revised...............................6564
552.215-72  Removed.................................................6564
552.215-73  Introductory text revised...............................6564
552.215-74  Introductory text revised...............................6564
552.219-1  Added...................................................16393
552.219-70  Revised................................................16393
552.222-87  Temporary Reg. AC-87-2 added...........................12182
    Temporary Reg. AC-87-2, Supp. 1 added..........................37618
552.225-70  Revised..................................................280
552.225-71  Revised..................................................280
552.225-72  Revised..................................................280

[[Page 392]]

552.225-73  Introductory text revised................................280
552.225-74  Introductory text revised................................280
552.232-8  Amended.................................................47006
552.242-70  Temporary Reg. AC-86-6, Supp. 1 added...................1333
    Revised........................................................21057
553.173  (c) table amended.........................................34389
553.270-1  Revised.................................................28828
553.270-2  (a) and (b) revised.....................................28828
553.270-3  (e) revised.............................................21057
553.272  (a) revised...............................................47006
553.273  (a) revised...............................................47007
553.370-3507  GSA Form 3507 amended................................21057
553.370-3584  GSA Form No. 3584....................................34389

                                  1988

48 CFR
                                                                   53 FR
                                                                    Page
Chapter 3
301.105  Table amended.............................................15562
301.304  (d) table amended.........................................43206
301.602-3  Added...................................................43206
301.603--301-670-3 (Subpart 301.6)  Revised........................15562
302.100  Amended...................................................43207
304.170  Removed...................................................43207
304.7005  Amended..................................................15563
305.102  Removed...................................................43207
305.303 (Subpart 305.3)  Added.....................................43207
306.501  Amended...................................................15563
306.501  Amended...................................................43207
307.105-2  (a)(3) amended..........................................15563
307.105-2  (a) (1) and (2) amended; (a) (3), (4), and (9) revised; 
        (a)(11) removed; (a) (12) through (15) redesignated as (a) 
        (11) through (14); new (a) (11) and (12) amended...........43207
    (a)(9) heading corrected.......................................44551
313.104  (h), (i), and (j) redesignated as (i), (j), and (k).......15563
315.406-5  (a)(2)(xv) amended; (a)(2) (xvi) and (xviii) removed; 
        (a)(2)(xvii) redesignated as (a)(2)(xvi) and amended.......43207
315.408  Amended...................................................43208
315.608-71  (a)(1) amended.........................................15563
315.905-71  (b) amended............................................15563
315.905-73  (b)(1) amended.........................................15563
315.905-74  Amended................................................15563
315.7002  (a) amended..............................................15563
317.206  Amended...................................................43208
317.7100--317.7102 (Subpart 317.71)  Revised.......................43208
319.870  (a) (2) and (4) amended...................................43208
330.7000--330.7002-6 (Subpart 330.70)  Removed.....................15563
332.770  Removed...................................................15563
332.902--332.905 (Subpart 332.9)  Added............................43208
332.905  (a)(2)(ii) and (b)(3) corrected...........................44551
333.203--333.214 (Subpart 333.2)  Added............................15563
339.7001  Introductory text, (a), and (b) amended..................43208
339.7002  (a) and (b) (2) and (3) amended..........................43208
342.7200--342.7206-3 (Subpart 342.72)  Removed.....................43209
352.202-1  Introductory text amended...............................15564
352.208.70  Removed................................................15564
352.215-70  Removed................................................15564
352.225-12  Removed................................................15564
352.232-72  Removed................................................15564
352.237-71  Removed................................................15564
352.242-70  Removed................................................15564
352.242-72--342.242-79  Removed....................................43209
352.243-70  Removed................................................15564
352.247-70  Removed................................................15564
352.270-6  Removed.................................................15564
352.270-8  Removed.................................................15564
352.370  Amended...................................................15564
Chapter 4
404.670  Added......................................................6062
404.7001 (Subpart 404.70)  Added....................................6062
407.305  Added......................................................6063
409.504  Added......................................................6063
410.011  Added......................................................6063
412  Added..........................................................6063
414.201--414.201-6 (Subpart 414.2)  Added...........................6063
415.407  Added......................................................6063
415.608  Added......................................................6063
415.1070  Added.....................................................6063
416.404-2  Revised..................................................6063
416.405  Added......................................................6065
416.470  Added......................................................6065
416.505--416.570 (Subpart 416.5)  Added.............................6065
416.603-4  Added....................................................6065
416.670  Added......................................................6065
417.208 (Subpart 417.2)  Added......................................6065
419.508  Added......................................................6066
422.7001--422.7005 (Subpart 422.70)  Added..........................6066
424.104 (Subpart 424.1)  Added......................................6066

[[Page 393]]

425.402--425.407 (Subpart 425.4)  Added.............................6067
428.102-3  Revised..................................................6067
428.310  Added......................................................6067
432.103  Added......................................................6067
432.111  Revised....................................................6067
432.7000--432.7004 (Subpart 432.70)  Removed........................6067
436.370  Amended....................................................6067
436.570--436.579 (Subpart 436.5)  Revised...........................6067
437.110  Added......................................................6068
437.270  Added......................................................6068
439.7001  Revised...................................................6068
    Heading corrected..............................................12748
439.7002  Revised...................................................6068
442.704 (Subpart 442.7)  Added......................................6069
445.106 (Subpart 445.1)  Added......................................6069
445.302-7  Added....................................................6069
446.370 (Subpart 446.3)  Added......................................6069
447  Added..........................................................6069
452.204-70--452.252-70 (Subpart 452.2)  Revised.....................6069
452.236-77  Heading corrected......................................12748
Chapter 5
501.102  Revised.....................................................130
501.103  (b) revised.................................................130
501.105  Introductory text republished; table amended (OMB 
        numbers).....................................................130
501.105  Table amended (OMB numbers)...............................51107
501.170-3  Revised...................................................131
501.170-4  (a) revised...............................................131
    (a) corrected...................................................1540
501.171-1  Revised...................................................131
501.171-2  Revised...................................................131
501.402  Revised.....................................................131
501.403  Revised.....................................................132
501.404  Revised.....................................................132
501.602-3  Temporary Reg. AC-88-1 added.............................7366
501.603  Temporary Reg. AC-87-4 added................................132
501.675  Temporary Reg. AC-88-1 added...............................7366
501.675-1  Temporary Reg. AC-88-1 added.............................7366
501.675-2  Temporary Reg. AC-88-1 added.............................7366
501.675-3  Temporary Reg. AC-88-1 removed...........................7366
504.803  (a) (23) and (24) combined as (a)(23) and revised; (a) 
        (25) through (29) redesignated as (a) (24) through (28) 
        and revised................................................30842
504.805  Revised...................................................30842
505.301  Temporary Reg. AC-88-2 added..............................28886
507.305  Temporary Reg. AC-87-1, Supp. 2 added.....................10395
    Temporary Reg. AC-87-1, Supp. 3 added..........................36580
507.306  Temporary Reg. AC-87-1, Supp. 2 added.....................10395
    Temporary Reg. AC-87-1, Supp. 3 added..........................36580
513.203-1  Temporary Reg. AC-87-4 added..............................132
513.404  Temporary Reg. AC-87-4 added................................132
513.505-3  Temporary Reg. AC-87-4 added..............................133
    Correctly designated............................................1441
513.7001  Temporary Reg. AC-87-4 added...............................133
514.201-6  (a) removed.............................................30842
514.301-70  Revised................................................30842
514.304-1  Revised.................................................30842
514.370  Revised...................................................30842
514.401  (a) introductory text, (1), and (4) revised and (c) added
                                                                   30842
514.402-1  (a) revised.............................................30843
514.402-3  (a) revised.............................................30843
514.406-3  (b) and (c) revised.....................................30843
514.406-4  Revised.................................................30843
514.407-1  Added...................................................17949
514.408-1  Temporary Reg. AC-88-2 added............................28886
514.414  Added.....................................................17949
515.407  (a) removed...............................................30843
515.411  Revised...................................................30843
515.411-70  Revised................................................30843
515.412  Added.....................................................30843
515.1070  Revised..................................................30844
519.502-1  Revised.................................................33812
519.701  Temporary Reg. AC-88-3 added..............................48911
519.702  Temporary Reg. AC-88-3 added..............................48911
519.704  Temporary Reg. AC-88-3 added..............................48911
519.705-2  Temporary Reg. AC-88-3 added............................48911
519.705-4  Temporary Reg. AC-88-3 added............................48911
519.705-5  Temporary Reg. AC-88-3 added............................48912
519.705-6  Temporary Reg. AC-88-3 added............................48912
519.706  Added.....................................................33812

[[Page 394]]

519.706-70  Temporary Reg. AC-87-3, Supp. 1 added..................21824
    Added..........................................................33812
    Added..........................................................33813
519.706-70  (b) and (d) corrected..................................39096
    Temporary Reg. AC-88-3 added...................................48912
519.708  Temporary Reg. AC-88-3 added..............................48913
519.770-1  (b)(1)(i) revised.......................................33813
519.770-1  (b)(1)(i) corrected.....................................39096
    Temporary Reg. AC-88-3 added...................................48913
519.770-3  Temporary Reg. AC-87-3, Supp. 1 added...................21824
519.770-3  Temporary Reg. AC-88-3 added............................48913
522.302  Revised...................................................51108
522.303  Removed...................................................51108
522.4  Revised.....................................................51108
522.1007  (a) revised..............................................30844
525.202--525.205 (Subpart 525.2)  Added.............................9629
525.401  Temporary Reg. AC-88-2 added..............................28886
525.402  Temporary Reg. AC-86-8, Supp. 2 added......................1925
    (a) and (c) revised.............................................4170
525.402-70  Temporary Reg. AC-88-2 added...........................28886
532.111  Temporary Reg. AC-88-1 added...............................7366
532.606-70  Revised................................................30844
532.904  Temporary Reg. AC-88-1 added...............................7366
532.908  Temporary Reg. AC-88-1 added...............................7366
534.002-70  Revised................................................30844
536.201  (c) revised...............................................30844
537.110  (a) and (b) revised.......................................30844
542.1203 (Subpart 542.12)  Added...................................34090
552.207-71  Temporary Reg. AC-87-1, Supp. 2 added..................10395
    Temporary Reg. AC-87-1, Supp. 3 added..........................36580
552.210-78  Revised................................................30844
552.210-79  Introductory text revised..............................30845
552.214-71  Removed................................................30845
552.215-71  Removed................................................30845
552.219-72  Temporary Reg. AC-88-3 added...........................48913
552.222-70--552.222-80  Removed....................................51108
552.222-81  Revised................................................51109
552.225-75  Added...................................................9630
552.232-70  Temporary Reg. AC-88-1 added............................7367
552.232-71  Temporary Reg. AC-88-1 added............................7367
552.232-72  Temporary Reg. AC-88-1 added............................7368
552.232-73  Temporary Reg. AC-88-1 added............................7368
552.237-1  Redesignated as 552.237-70 and introductory text 
        revised....................................................30845
552.237-70  Redesignated from 552.237-1 and introductory text 
        revised....................................................30845
552.237-71  Introductory text revised..............................30845
552.237-72  Introductory text revised..............................30845
552.300  Amended...................................................17950
553.173  (c) table amended.........................................51109
553.270-1  Revised.................................................51109
553.270-3  (c) revised.............................................51109
553.370  Amended...................................................30845
    Correctly designated...........................................32820
Chapter 5  Appendix C removed......................................30842
Chapter 6
Chapter 6  Chapter established.....................................26159
601--604 (Subchapter A)  Added.....................................26159
601  Added.........................................................26159
602  Added.........................................................26162
603  Added.........................................................26163
604  Added.........................................................26163
604.7001  Corrected................................................36461
605--609 (Subchapter B)  Added.....................................26164
605  Added.........................................................26164
606  Added.........................................................26165
606.101-70  Corrected..............................................36461
608  Added.........................................................26165
609  Added.........................................................26165
609.404  Correctly designated......................................36461
609.406-3  (a)(2)(iii) and (b)(6) corrected........................36461
613--617 (Subchapter C)  Added.....................................26167
613  Added.........................................................26167
614  Added.........................................................26168
614.102-70  Corrected..............................................36461
615  Added.........................................................26168
616  Added.........................................................26169
616.603-2  Corrected...............................................36462
616.603-70  Corrected..............................................36461
617  Added.........................................................26169
619--625 (Subchapter D)  Added.....................................26170
619  Added.........................................................26170
622--625  Added....................................................26172
628--633 (Subchapter E)  Added.....................................26173
628--630  Added....................................................26173

[[Page 395]]

632  Added.........................................................26173
633  Added.........................................................26173
634--637 (Subchapter F)  Added.....................................26175
634  Added.........................................................26175
634.001-70  Corrected..............................................36462
636  Added.........................................................26175
637  Added.........................................................26176
642--648 (Subchapter G)  Added.....................................26176
642  Added.........................................................26176
643  Added.........................................................26176
645  Added.........................................................26177
646  Added.........................................................26177
648  Added.........................................................26177
652--653 (Subchapter H)  Added.....................................26177
652  Added.........................................................26177
652.202-70  Corrected..............................................36462
652.242-72  Corrected..............................................36462
653  Added.........................................................26180
670 (Subchapter I and Part)  Added.................................26188
670.102  (b)(3) corrected..........................................36462

                                  1989

48 CFR
                                                                   54 FR
                                                                    Page
Chapter 3
301.102  Amended...................................................24342
301.201  (a) and (b) amended.......................................24342
301.270  (a) and (b) amended.......................................24342
301.304  (a), (c), and (d) amended.................................24342
301.403  Amended...................................................24342
301.404  Amended...................................................24342
301.470  Amended...................................................24342
301.670-2  (a) removed; (b) and (c) redesignated as (a) and (b); 
        new (a) heading amended....................................24342
302.100  Amended............................................24342, 43965
303.104  Added.....................................................31528
303.104-4  Added; interim..........................................31528
303.104-5  Added; interim..........................................31528
303.104-6  Added; interim..........................................31529
303.104-9  Added; interim..........................................31529
303.104-11  Added; interim.........................................31529
303.104-12  Added; interim.........................................31529
303.303  Amended...................................................24342
303.409  (b)(4) amended............................................24342
303.502  (b) amended...............................................24342
304.870  (c)(4) amended............................................24342
    (c)(5) amended.................................................43965
304.7001  (b)(1), (c) and (d) amended..............................24342
304.7101  (c) amended..............................................24342
305.202  (b) amended...............................................24342
306.501  Amended...................................................24342
307.7003  (b)(2) amended...........................................24342
307.7004  (c) amended..............................................24342
307.7102  (e) amended..............................................24342
309.403  Amended............................................24342, 43965
309.404  (c) amended........................................24342, 43965
309.470-1  Amended.................................................24342
314.406-3  (e) and (g)(3) amended..................................24342
314.406-4  (c) amended.............................................24342
315.406-2  (a)(3) amended..........................................24342
315.406-5  (a)(2) (xiv) and (xv) amended; (xvi) removed; new (iii) 
        added; (iii) through (xv) redesignated as (iv) through 
        (xvi)......................................................24342
    (a)(2) amended.................................................43966
315.407  (i) added.................................................43966
316.702  (d)(2), (f) (1), and (4) amended..........................24342
317.7002  (b) (1) through (3) amended..............................24342
319.201-70  (a) amended............................................24342
322.604-2  (c)(1) amended..........................................24342
324.2  Revised.....................................................24342
330.2  Added.......................................................24344
330.3  Removed.....................................................24344
332.905  Revised...................................................43966
333.102  (c) (1) and (3) amended...................................24344
333.103  (a) amended...............................................24344
333.104  (a)(6), (b) (1), (2), (c)(2), and (f) amended.............24344
333.213  (a) amended...............................................24344
335.070-4  (c) (1) and (2) amended.................................24344
342.7002  (e) added................................................43966
    (e) corrected..................................................47750
352.215-71  Removed................................................24344
352.242-80  Removed................................................43966
352.370  (b) amended...............................................24344
    (a), (b), and (c) redesignated as (c), (d), and (e); new (a) 
and (b) added; new (c) amended; new (e) revised; clauses revised 
                                                                   26751
Chapter 5
501--570 (Chapter 5)  Revised......................................26486
501.602-3  Added....................................................9050
501.670-1  Revised.................................................13887
501.670-2  Revised.................................................13887
501.670-3  Revised.................................................13888
501.670-4  Revised.................................................13888
501.670-5  Revised.................................................13889
501.670-6  Revised.................................................13889
501.675--501.675-3  Removed.........................................9050
501.707  Table 501-1 amended.......................................51885
502.101  Corrected.................................................40059
503.104  Temporary Reg. AC-89-2 added..............................29721

[[Page 396]]

    Temporary Reg. AC-89-2 removed.................................51745
503.104-4  Temporary Reg. AC-89-2 added............................29721
    Temporary Reg. AC-89-2 removed.................................51745
503.104-5  Temporary Reg. AC-89-2 added............................29721
    Temporary Reg. AC-89-2 removed.................................51745
503.104-9  Temporary Reg. AC-89-2 added............................29722
    Temporary Reg. AC-89-2 removed.................................51745
503.104-10  Temporary Reg. AC-89-2 added...........................29722
    Temporary Reg. AC-89-2 removed.................................51745
503.104-11  Temporary Reg. AC-89-2 added...........................29722
    Temporary Reg. AC-89-2 removed.................................51745
503.104-12  Temporary Reg. AC-89-2 added...........................29722
    Temporary Reg. AC-89-2 removed.................................51745
504.803  (a)(23) corrected.........................................40060
505.301  Removed...................................................10149
505.302  Removed...................................................10149
505.303  Revised...................................................10149
505.303-70  (b)(3)(iii) revised....................................40060
    Temporary Reg. AC-89-2 removed.................................51745
    Revised........................................................10149
    Temporary Reg. AC-89-2; (b)(2) revised; (b)(4) and (c) removed
                                                                   29722
505.403  Revised...................................................10150
    Revised (temporary)............................................29722
    Temporary Reg. AC-89-2 removed.................................51745
509.407-3  (b)(6)(iii) revised.....................................40060
512.104  (d) and (e) revised.......................................11955
514.201-2  Revised..................................................9050
515.406-2  Removed.................................................51885
519.704  (c)(2) revised............................................40060
525.402  Temporary Reg. AC-89-3 added..............................33554
532.70  Temporary Reg. AC-89-1 added...............................14235
532.111  (b), (c), (d) (2) and (3), and (e) removed; (d)(1), (f), 
        and (g) redesignated as (b), (c), and (d); new (b) revised
                                                                    9050
    Temporary Reg. AC-89-1 added...................................14235
532.232-8  Temporary Reg. AC-89-1 added............................14235
532.232-70  Temporary Reg. AC-89-1 added...........................14235
532.232-71  Temporary Reg. AC-89-1 added...........................14235
532.232-73  Temporary Reg. AC-89-1 added...........................14235
532.232-75  Temporary Reg. AC-89-1 added...........................14235
532.232-76  Temporary Reg. AC-89-1 added...........................14235
532.905--532.908 (Subpart 532.9)  Added.............................9050
532.905  Temporary Reg. AC-89-1 added..............................14235
532.905-70  Temporary Reg. AC-89-1 added...........................14235
532.905-71  Temporary Reg. AC-89-1 added...........................14235
532.908  Temporary Reg. AC-89-1 added..............................14235
532.7000  Removed...................................................9051
532.7001--532.7003 (Subpart 532.70)  Added.........................43180
532.7002  Removed...................................................9051
532.7004  Removed...................................................9051
536.203  (c) revised...............................................51886
542.1107  (c) removed..............................................11955
546.301  Removed...................................................11955
546.302  Revised...................................................11955
546.302-70  Revised................................................11955
546.302-71  Revised................................................11956
546.302-72  Removed................................................11956
546.316  Removed...................................................11956
546.316-70  Removed................................................11956
552.203-8  Added (temporary).......................................29722
552.203-8  (Temporary Reg. AC-89-2) removed........................51745
552.203-10  Added (temporary)......................................29722
    Temporary Reg. AC-89-2 removed.................................51745
552.203-71  Added (temporary)......................................29723
    Temporary Reg. AC-89-2 removed.................................51745
552.210-79  Revised................................................43180
552.212-1  (b) amended.............................................51886
552.212-72  Revised................................................11956
    Introductory text revised......................................40060
552.215-75  (c) revised............................................40060
    Removed........................................................51886
552.216-71  Amended.................................................6932
552.219-71  Introductory text revised..............................40060
552.219-72  Heading and provision heading revised..................40060

[[Page 397]]

552.225-70  Amended................................................40060
552.228-75  Introductory text revised..............................40060
552.232-8  Temporary Reg. AC-89-1 added............................14235
552.232-70  Revised.................................................9051
552.232-70  Temporary Reg. AC-89-1 added...........................14235
552.232-71  Revised.................................................9051
552.232-71  Temporary Reg. AC-89-1 added...........................14235
552.232-72  Revised.................................................9052
552.232-73  Removed.................................................9052
    Temporary Reg. AC-89-1 added...................................14235
552.232-75  Introductory text revised...............................9052
    Temporary Reg. AC-89-1 removed.................................14235
552.232-76  Introductory text revised...............................9052
    Temporary Reg. AC-89-1 removed.................................14235
552.232-78  Introductory text amended...............................9052
    (c) amended....................................................40060
552.232-79  Introductory text amended...............................9052
552.232-80  Added..................................................43181
552.236-73  Amended................................................40061
552.237-72  (a) revised............................................40060
552.242-70  Revised................................................11956
552.242-72  Removed................................................11956
552.246-17  (c)(7) revised.........................................40061
552.246-70  Revised................................................11956
552.246-72  Removed; new 552.246-72 redesignated from 552.246-73 
        and revised................................................11957
552.246-73  Redesignated as 552.246-72 and revised.................11957
552.246-74  Removed................................................11958
552.246-77  Removed................................................11958
552.249-70  (b) revised............................................40061
553.370-2419  Revised..............................................14237
553.370-2932  Removed..............................................10150
553.370-3501  GSA Form 3501 availability............................3605
570.208-3  Temporary Reg. AC-89-4 added; eff. 11-30-90.............49090
    Revised; eff. 11-30-90.........................................49090
570.501  Temporary Reg. AC-89-4 added; eff. 11-30-90...............49090
    (d) revised; eff. 11-30-90.....................................49090
570.602  (c) revised...............................................40061
Chapter 5  Appendix A availability..................................3605

                                  1990

48 CFR
                                                                   55 FR
                                                                    Page
Chapter 3
302.100  Amended...................................................13536
303.104  Suspended; eff. to 11-30-90................................2078
303.104-4  Suspended; eff. to 11-30-90..............................2078
303.104-5  Suspended; eff. to 11-30-90..............................2078
303.104-6  Suspended; eff. to 11-30-90..............................2078
303.104-9  Suspended; eff. to 11-30-90..............................2078
303.104-11  Suspended; eff. to 11-30-90.............................2078
303.104-12  Suspended; eff. to 11-30-90.............................2078
306.501  Amended...................................................42197
314.202-7--314.213 (Subpart 314.2)  Added..........................13536
315.402  Added.....................................................13536
315.471  Added.....................................................13536
316.307  Added.....................................................42197
317.7002  (b)(3) amended...........................................13536
319.800--319.870 (Subpart 319.8)  Revised..........................13536
332.402  (e) amended...............................................42197
332.406  (c)(2) amended............................................42197
332.407  (d) introductory text amended.............................42197
332.409-1  Amended.................................................42197
332.501-2  (a)(3) amended..........................................42197
333.104  (b)(1) and (c)(2) amended.................................42197
352.216-7  Removed.................................................42197
352.216-71  Removed................................................42197
352.216-72  Added..................................................42197
352.370 (Subpart 352.3)  Removed...................................42198
Chapter 4
415.413  Added......................................................7334
Chapter 5
501.105  Amended...................................................48847
501.602-1  Temporary Reg. AC-90-1 added; (i) revised; (k), (l), 
        and (m) added..............................................13277
501.603-3  Temporary Reg. AC-90-1 (a) revised......................13278
501.603-70  Temporary Reg. AC-90-1 (c) amended; (d)(2), (4), (f), 
        and (h)(6) revised; (h)(1)(ix) added.......................13278
501.707  Table 501-1 amended.......................................37879
502.101  Amended...................................................48847
503.104  Added.....................................................39972
503.104-4  Added...................................................39972

[[Page 398]]

503.104-5  Added...................................................39972
    (c)(4) revised.................................................50700
503.104-7  Added...................................................39973
    (a) revised....................................................50700
503.104-8  Added...................................................39973
503.104-9  Added...................................................39973
503.104-10  Added..................................................39973
503.104-11  Added..................................................39974
503.104-12  Added..................................................39974
503.804--503.806 (Subpart 503.8)  Added............................29580
504.203  Added......................................................8954
504.803  (a) (23) and (25) revised.................................39974
505.303-70  (b)(2) revised; (b)(4) and (c) added...................39974
505.403  Added.....................................................39974
506.302-1  Revised.................................................48847
506.304  Revised...................................................48847
507.102  Revised...................................................28631
507.104  (a) and (d) revised.......................................28631
507.105  (a)(3) and (b) revised....................................28631
509.405  Revised...................................................37880
513.106  (a) revised...............................................48847
513.107  Removed...................................................48847
513.505-70  (a) revised............................................20458
    (b) revised; (c) added.........................................48847
513.7001  (g) amended..............................................48847
514.201-70  (c) revised............................................20458
514.202-7  Added...................................................20458
514.213  Added.....................................................20458
514.301-70  Removed................................................20458
515.402  (c) added.................................................20458
515.414  Revised...................................................48847
515.414-70  (c) revised............................................20458
    (d) revised....................................................48847
515.501  Revised...................................................20458
    Revised........................................................48848
515.612  Added.....................................................39974
515.803  Revised...................................................48848
515.905  (c) added.................................................48848
515.905-1  (a) revised.............................................48848
516.203-4  Revised.................................................39278
516.301-3  Revised.................................................39279
517.208  Added.....................................................39279
522.1001  Revised..................................................37880
522.1003-3  Added..................................................37880
522.1003-4  Revised................................................37880
522.1003-7  Revised................................................37880
522.1011-2  Revised................................................37880
522.1021  Revised..................................................37880
522.1403  Revised..................................................37880
525.402  Temp. Reg. AC-89-5..........................................421
    (a) revised.....................................................6256
    (b) and (c) revised............................................32635
    Temp. Reg. AC-90-2.............................................46069
525.406  Added.....................................................38552
525.407  Temp. Reg. AC-90-2........................................46069
525.1003--525.1004 (Subpart 525.10)  Added.........................37880
528.101-4  Removed..................................................5223
528.103-2  (c) and (d) revised......................................5223
    Technical correction............................................7967
528.103-3  (b) and (c) revised......................................5223
    Heading corrected...............................................7967
528.106-1  Added....................................................5223
528.202  Revised....................................................5223
528.202-1  Removed..................................................5223
528.202-2  Removed..................................................5223
528.202-70  Revised.................................................5223
528.202-71  Removed.................................................5223
528.203  Revised....................................................5223
528.203-7  Added....................................................5223
528.204  Added......................................................5224
528.270  Removed....................................................5224
545.302-1 (Subpart 545.3)  Added....................................8954
552.203-5  (b) amended..............................................6256
552.203-71  Added..................................................39974
552.203-72  Added..................................................39975
    Amended........................................................50701
552.203-73  Added..................................................39975
552.209-74  Revised.................................................8954
552.216-72  Added..................................................39279
552.217-70  Added..................................................39280
552.219-1  Revised..................................................8954
552.225-8  Temp. Reg. AC-90-2......................................46069
552.225-9  Temp. Reg. AC-90-2......................................46069
552.228-72  Revised.................................................5224
    (b) amended.....................................................9887
552.228-73  Revised.................................................5224
552.228-74  Removed.................................................5224
552.229-72  Revised.................................................6256
570.208-2  (a) and (e) revised.....................................11588
570.208-3  Revised.................................................11588
570.208-5  (b) revised.............................................11588
570.501  (d) revised...............................................11588
Chapter 6
601.602-1  (c) amended..............................................5774
605.404--605.404-1 (Subpart 605.4)  Added...........................5774
607  Added..........................................................5774
608.302 (Subpart 608.3)  Added......................................5774
609.404  Heading revised............................................5774
622.302 (Subpart 622.3)  Added......................................5774
622.404--622.406-12 (Subpart 622.4)  Added..........................5774
622.1308  Added.....................................................5775
622.1408  Added.....................................................5775
623  Heading revised................................................5775
623.506 (Subpart 623.5)  Added......................................5775
625.901 (Subpart 625.9)  Revised....................................5775
625.1003 (Subpart 625.10)  Added....................................5775
632.903 (Subpart 632.9)  Added......................................5775

[[Page 399]]

636.602  Revised....................................................5775
637.110  Added......................................................5775
648.102  Revised....................................................5775
648.201 (Subpart 648.2)  Added......................................5775
653.107  Removed....................................................5775

                                  1991

48 CFR
                                                                   56 FR
                                                                    Page
Chapter 3
302.100  Amended...................................................47002
304.870  (c)(1) and (2) amended....................................47002
306.304  (a)(1) amended............................................47002
307.170  (a)(1), (2) and (b) amended...............................47002
307.170-1  (a)(1), (2), (b)(1) and (2) amended.....................47002
307.170-2  (a)(1), (2) and (b) amended; (a)(3) added...............47002
313.106  (a), (b) introductory text, (4)(i)(D), (c) introductory 
        text and (2) amended.......................................47002
313.107  (d) redesignated as (e)...................................47003
313.204  (e) redesignated as (e)(5) and amended....................47003
315.406-5  (b)(3)(ii)(c) redesignated as (b)(3)(ii)(C) and amended
                                                                   47003
315.905-71  (d) amended............................................47003
315.7002  (a) amended..............................................47003
328  Added.........................................................58316
333.102  (c) redesignated as (d)...................................47003
333.103  (a) redesignated as (a)(2); (b)(1) designation removed 
        and text transferred to (b) introductory text; (b) 
        introductory text and (2) redesignated as (a)(3) and (4); 
        new (a)(3) amended.........................................47003
333.104  (a)(2) through (6) redesignated as (a)(3) through (7); 
        new (a)(3)(vii), (viii), (4), (5), (6)(i) and (c)(6) 
        amended; (f) and (h) redesignated as (g) and (i); new (g) 
        and (i) amended............................................47003
333.105  (b)(10) amended...........................................47003
352.228-7  Added...................................................58316
352.228-70  Removed................................................58317
352.252-2  Removed.................................................47003
352.270-6  Added; interim..........................................33882
    Technical correction...........................................37668
    Regulation at 56 FR 33882 confirmed; (a) amended...............54797
    Corrected......................................................57602
Chapter 5
501.105  Revised (OMB numbers).....................................64213
501.404  (c) revised...............................................15288
501.602-1  (i) revised; (k) through (m) added......................15288
501.602-2  (a) and (b)(1) revised; (c) amended.....................15288
501.603-3  Revised.................................................15288
501.603-4  Revised.................................................15288
501.603-70  (a), (d)(2) through (4), (h)(1) introductory text, 
        (iv)(C), (v), (vi)(C), (E), (vii) through (ix) and (h)(2) 
        through (4) revised; (c) and (f) amended; (h)(1)(x) and 
        (i) added; (h)(5) and (6) removed..........................15289
501.670-4  (a) introductory text, (4), (5), (26), (d) introductory 
        text and (1) through (4) revised...........................47004
502.101  Amended...................................................47004
504.470  Revised...................................................47004
504.470-1  Revised.................................................47004
504.470-2  Revised.................................................47004
504.471  (b) revised...............................................47005
504.476  Revised...................................................47005
507.103  Added......................................................2864
508.602  Removed...................................................33721
509.405  Revised...................................................51660
509.406-3  (b)(9) revised..........................................47005
510.001  Revised....................................................2864
510.002  Added......................................................2865
    Revised........................................................33721
513.7001  (g) revised..............................................47005
514.203-1  (a) revised.............................................47005
514.404-2  (a) revised.............................................47005
515.407  Removed...................................................47006
515.408  Added.....................................................47005
515.411  (b) revised...............................................47005
515.1001  Added....................................................47005
515.1070  (a) revised..............................................47005
516.505 (Subpart 516.5)  Added.......................................376
519.201  Added.....................................................26769
    Corrected......................................................30618
519.202-2  (b)(4) added.............................................3044
519.202-5  (b) revised..............................................3044
519.302  Revised....................................................3044
519.304  Revised...................................................47006
519.500  Revised....................................................3044
519.704  (a)(2) and (3) revised.....................................3044
    (c)(2) revised.................................................59220
519.705-2  Revised.................................................64213
519.705-4  (d) redesignated as (f); (c) and new (f)(1) revised; 
        new (d) and (e) added.......................................3044

[[Page 400]]

    (d) revised; (e) removed; (f)(1) through (3) redesignated as 
(e)(1) through (3) and revised.....................................26922
    (a) revised....................................................59220
    (a)(5) revised.................................................64214
519.705-5  (c) and (d) amended......................................3044
519.706-70  Revised.................................................3045
    (e) revised....................................................26922
    (f)(2)(iii) revised............................................64214
519.708  Revised...................................................64214
519.770-1  (a)(2), (b)(1)(ii), (iii) and (2)(ii) revised............3045
519.803--519.803-70 (Subpart 519.8)  Added.........................26769
523.303  Revised....................................................1740
524.202  Revised...................................................47006
525  Temporary Reg. AC-90-2, Supp. 1 added.........................52479
533.103  Revised...................................................47006
538.000  Revised...................................................29443
538.203-71  Revised................................................29443
546.710  (a) revised................................................1741
547.303-6  Removed.................................................47006
549.001  Removed...................................................33722
549.402-6  (c) revised.............................................33722
549.402-7  (a) and (b)(2) revised..................................33722
552  Temporary Reg. AC-90-2, Supp. 1 added.........................52479
552.203-70  Revised..................................................965
552.215-73  Removed................................................47006
552.215-74  Removed................................................47006
552.216-73  Added....................................................376
552.219-1  Amended.................................................47006
552.219-70  Removed................................................47007
552.219-72  Introductory text revised..............................64214
552.219-73  Added..................................................64214
552.223-70  Introductory text revised...............................1741
552.223-72  Added...................................................1741
552.225-9  Corrected.................................................377
552.225-72  Temp. Reg. AC-91-2.....................................11692
552.238-70  Added..................................................29443
    Amended........................................................51660
552.242-70  Revised.................................................1741
552.246-17  Revised.................................................1741
552.246-70  Revised.................................................1742
552.246-72  Revised.................................................1744
552.247-34  Removed................................................47007
570.702-1  Temp. Reg. AC-91-1.......................................4735
570.702-2  Temp. Reg. AC-91-1.......................................4735
570.702-5  Temp. Reg. AC-91-1.......................................4735
570.702-11  Temp. Reg. AC-91-1......................................4735
570.702-14  Temp. Reg. AC-91-1......................................4735
570.702-15  Temp. Reg. AC-91-1......................................4735
570.702-17  Temp. Reg. AC-91-1......................................4735
570.702-18  Temp. Reg. AC-91-1......................................4735
570.702-19  Temp. Reg. AC-91-1......................................4735
570.702-21  Temp. Reg. AC-91-1......................................4735

                                  1992

48 CFR
                                                                   57 FR
                                                                    Page
Chapter 3
305.303  (a) amended...............................................11689
306.303-1  (g)(1) and (2) amended..................................11689
306.302-1  (b)(4)(i) designation removed; (b)(4)(ii) redesignated 
        as (c) and amended.........................................11689
313.105  Revised...................................................11689
315.407  (h) and (i) redesignated as (g) and (n)...................11690
319.201-70  (d)(3) amended.........................................11690
319.501  Revised...................................................11690
319.505  Amended...................................................11690
319.705-3  Amended.................................................11690
319.705-4  (c) removed.............................................11690
332.702  (a) revised...............................................35473
333.103  (a)(4) amended............................................35473
Chapter 5
501.103  (b) revised...............................................37889
501.105    Revised (OMB numbers)...................................14648
501.170-1  Revised.................................................14649
501.603-70  (h)(1)(ii) and (v) revised.............................14649
    (h)(1)(iv)(K) revised..........................................61583
501.670-4  (a)(3) revised..........................................61583
502.101  Revised....................................................9213
    Amended........................................................61583
503.104-10  (a) and (b) revised....................................37889
503.404  (a) revised...............................................37889
504.201  Revised...................................................61583
504.803  (a)(23) revised...........................................61584
505.101  (c)(2) revised............................................37889
505.203  (b) revised...............................................37890
508.304-5  Revised.................................................61584
508.371  Removed...................................................61584
510.011  (j) added.................................................61584
513.505-2  (c) revised..............................................7555
513.7001  (a), (b)(1) and (g) revised..............................26609
514.406-3  Revised.................................................14649
515.406-1  (a) revised.............................................61584
515.414-70  (b) revised............................................61584
515.804-3  Temporary Reg. AC-92-1 paragraph (c) added...............5864
515.804-70  Temporary Reg. AC-92-1 added............................5864
517.200  Added.....................................................59939

[[Page 401]]

517.201  Removed...................................................59939
517.202  Added.....................................................59939
517.203  Added.....................................................59939
517.204  Revised...................................................59939
517.207  Revised...................................................59939
517.208  Revised...................................................59939
519.202-5  Revised.................................................37890
519.304  Revised...................................................37890
519.708  (a) revised...............................................37890
522.000  Added......................................................7555
522.001  Added......................................................7555
522.101-1  Revised..................................................7556
522.101-3  Added....................................................7556
522.103-5  Added....................................................7556
522.406-13  Revised.................................................7556
522.807  Revised....................................................7556
522.1001  Removed...................................................7556
522.1003-4  Revised.................................................7556
522.1003-7  Revised.................................................7556
522.1006  (b) and (c) revised......................................22666
522.1013  Added.....................................................7556
522.1014  Added.....................................................7556
522.1021  Revised...................................................7556
522.1303  Revised...................................................7556
522.1403  Revised...................................................7556
525.402  (a) revised.................................................648
    (b) revised....................................................42708
525.407  Revised...................................................42708
530.201-5  Revised.................................................61584
530.470 (Subpart 530.4)  Added.....................................61584
532.502-3  Removed.................................................14649
532.908  (c) revised...............................................37890
533.104  (c) revised...............................................61584
538.203-70  Temporary Reg. AC-92-1 added............................5867
552  Temporary Reg. AC-91-2; Supp. 1 added.........................21041
552.217-71  Added..................................................59939
552.222-43  Revised................................................22666
552.270-10  Corrected..............................................52826
552.270-28  Corrected..............................................52826
552.270-37  Corrected..............................................52826
552.223-72  Amended................................................14649
552.225-8  Added...................................................42709
552.225-9  Added...................................................42709
552.225-72  Revised................................................42709
552.232-73  Revised................................................37890
552.232-74  Removed................................................14649
552.242-70  Revised................................................26609
552.270-3  Revised.................................................23163
552.270-6  Revised.................................................37890
552.270-10  Revised................................................37890
552.270-11  Revised................................................37891
552.270-12  Revised................................................37891
552.270-13  Revised................................................37891
552.270-14  Reserved...............................................37891
552.270-15  Revised................................................37891
552.270-16  Revised................................................37891
552.270-17  Revised................................................37891
552.270-18  Revised................................................37892
552.270-20  Revised................................................37892
552.270-21  Revised................................................37892
552.270-22  Revised................................................37892
552.270-24  Revised................................................37892
552.270-26  Reserved...............................................37893
552.270-27  Revised................................................37893
552.270-28  Revised................................................37893
552.270-29  Reserved...............................................37893
552.270-30  Revised................................................37893
552.270-31  Added..................................................37893
552.270-32  Added..................................................37893
552.270-33  Added..................................................37893
552.270-34  Added..................................................37894
552.270-35  Added..................................................37894
552.270-36  Added..................................................37894
552.270-37  Added..................................................37894
552.270-38  Added..................................................37894
552.270-39  Added..................................................37894
552.270-40  Added..................................................37894
570.201--570.210 (Subpart 570.2)  Heading revised..................37895
570.202  (a) revised...............................................37895
570.203  (a)(5), (8) and (9) revised; (a)(10) added................37895
    (a)(8)(vii) table and (9) corrected............................52826
570.204  (c)(3) revised............................................37895
570.206  (b) revised...............................................37895
570.208-1  (b) revised.............................................37896
570.208-3  (b)(5) added............................................37896
570.208-5  Revised.................................................37896
570.301--570.304-6 (Subpart 570.3)  Heading revised................37896
570.301  Revised...................................................37896
570.302  Revised...................................................37896
570.303  Revised...................................................37896
    Corrected......................................................52826
570.304  Revised...................................................37896
570.304-1  (b) revised.............................................37896
570.304-2  Revised.................................................37896
570.304-3  Revised.................................................37896
570.304-4  Revised.................................................37896
570.304-5  Revised.................................................37897
570.502  (a), (b)(1) and (3)(i) revised............................37897
570.503  (b) and (c) revised.......................................37897
570.504  (a) revised...............................................37897
570.602-2  (f)(3) revised..........................................37897
570.701-1  Revised.................................................37897
570.701-2  Revised.................................................37897
570.701-3  Revised.................................................37897
570.701-4  Revised.................................................37898

[[Page 402]]

570.701-5  Revised.................................................37898
570.701-6  Revised.................................................37898
570.702-1  Temp. Reg. AC-91-1, Supp. 1 added........................4939
    Revised........................................................37898
570.702-2  Temp. Reg. AC-91-1, Supp. 1 added........................4939
    Revised........................................................37898
570.702-3  Revised.................................................37898
570.702-4  Revised.................................................37898
570.702-5  Temp. Reg. AC-91-1, Supp. 1 added........................4939
    Removed........................................................37898
570.702-6  Revised.................................................37898
570.702-7  Revised.................................................37898
570.702-8  Revised.................................................37898
570.702-9  Revised.................................................37898
570.702-10  Revised................................................37898
570.702-11  Temp. Reg. AC-91-1, Supp. 1 added.......................4939
    Revised........................................................37898
570.702-12  Revised................................................37898
570.702-14  Temp. Reg. AC-91-1, Supp. 1 added.......................4939
    Revised........................................................37898
570.702-15  Temp. Reg. AC-91-1, Supp. 1 added.......................4939
    Revised........................................................37899
570.702-16  Revised................................................37899
570.702-17  Temp. Reg. AC-91-1, Supp. 1 added.......................4939
    Removed........................................................37899
570.702-18  Temp. Reg. AC-91-1, Supp. 1 added.......................4939
    Revised........................................................37899
570.702-19  Temp. Reg. AC-91-1, Supp. 1 added.......................4939
    Revised........................................................37899
570.702-20  Removed................................................37899
570.702-21  Temp. Reg. AC-91-1, Supp. 1 added.......................4939
    Revised........................................................37899
570.702-22  Added..................................................37899
570.702-23  Added..................................................37899
570.702-24  Added..................................................37899
570.702-25  Added..................................................37899
570.702-26  Added..................................................37899
570.702-27  Added..................................................37899
570.702-28  Added..................................................37899
570.702-29  Added..................................................37899
570.702-30  Added..................................................37900
    Heading corrected..............................................52826
570.702-31  Added..................................................37900
570.801  Revised...................................................37900
570.802  Revised...................................................37900

                                  1993

48 CFR
                                                                   58 FR
                                                                    Page
Chapter 5
501.105  Amended...................................................52443
501.603-3  Revised.................................................58284
501.603-4  Revised.................................................58284
501.603-70  (c) and (f) amended; (d)(1), (2), (4), (h)(1)(i), (4), 
        (i)(1), (2) and (3) revised................................58284
    (h)(1)(v) revised..............................................64694
501.670  Removed...................................................52443
501.670-1  Removed.................................................52443
501.670-2  Removed.................................................52443
501.670-3  Removed.................................................52443
501.670-4  Removed.................................................52443
501.670-5  Removed.................................................52443
501.670-6  Removed.................................................52443
501.704-70  (b)(2) removed.........................................52443
503.104-8  Revised.................................................52443
507.305  Removed...................................................52443
508.307-1  Revised.................................................52443
508.705-72  Removed................................................52443
509.106-1  Removed.................................................52443
509.106-2  Revised.................................................64694
509.405  Removed...................................................52443
509.406-3  (b)(6) through (9) redesignated as (b)(7) through (10); 
        new (b)(6) added...........................................26920
509.407-3  (b)(5) and (6) redesignated as (b)(6) and (7) and 
        revised; new (b)(5) added..................................26920
    (b)(7)(iii) corrected..........................................29254
511.001  Removed...................................................52443
514.201-72  Removed................................................52443
514.208  Removed...................................................52443
514.402-1  (i) revised.............................................52443
514.404-1  (b) revised.............................................52443
514.407-2  Removed.................................................52443
515.170  Removed...................................................52443
515.402  Revised...................................................52443
515.403  Removed...................................................52443
515.405-1  Revised.................................................52443
515.414-70  (a) revised............................................52443
515.506-1  Removed.................................................52443
519.705-5  (d) revised.............................................52444
519.705-6  (a) revised; (c) removed................................52444
519.770-1  (b)(2)(i) revised.......................................52444
519.770-3  (a) revised.............................................52444
522.1006  Revised..................................................47398
522.407  Removed...................................................52444
525.203  Revised; eff. 1-1-94 through 12-31-94.....................69243
525.205  Revised; eff. 1-1-94 through 12-31-94.....................69244
525.402  (a) amended; eff. 1-1-94 through 12-31-94.................69244

[[Page 403]]

525.1003--525.1004 (Subpart 525.10)  Removed.......................52444
528.102-3  Removed.................................................52444
528.106-70  Removed................................................52444
528.202  Revised...................................................52444
529.401-70  Revised................................................52444
529.401-71  Removed................................................52444
532.803  Removed...................................................52444
536.201  Revised...................................................52445
536.203  Revised...................................................52445
536.206  Removed...................................................52445
536.303  Removed...................................................52445
536.303-70  Revised................................................52445
536.303-71  (g) removed............................................52445
536.303-72  (c) removed; (d) redesignated as (c)...................52445
538.203-71  (c) added..............................................54524
542.302  (c) removed; (d) redesignated as (c)......................52445
543.202  Revised...................................................52445
552.207-70  Removed................................................52445
552.222-43  Corrected; CFR correction...............................8235
    Removed........................................................47399
552.222-82  Removed................................................52445
552.225-8  Revised; eff. 1-1-94 through 12-31-94...................69244
552.225-9  Revised; eff. 1-1-94 through 12-31-94...................69244
552.225-75  Revised; eff. 1-1-94 through 12-31-94..................69245
552.228-70  Introductory text revised..............................52446
552.238-74  Added..................................................54524
552.246-70  Amended................................................64694
570.208-1  (c) removed.............................................52446

                                  1994

48 CFR
                                                                   59 FR
                                                                    Page
Chapter 5
501.105  Revised (OMB numbers).....................................63260
516.505  Revised...................................................32384
519.701  Removed...................................................38933
519.702  Removed...................................................38933
519.704  Removed...................................................38933
519.705-2  Revised.................................................38933
519.705-4  Removed.................................................38933
519.705-5  Removed.................................................38933
519.705-6  Removed.................................................38933
519.706  Removed...................................................38933
519.706-70  Removed................................................38933
519.708  Revised...................................................38933
519.770  Removed...................................................38934
519.770-1  Removed.................................................38934
519.770-3  Removed.................................................38934
519.803-70  Revised................................................38934
525.203  Corrected..................................................5484
    Revised........................................................64856
525.205  Revised...................................................64857
525.402  (a) revised...............................................64857
533.105  (a)(1)(iii), (2) and (4) revised..........................22520
    (a)(4) corrected...............................................29480
533.7103-1  (b)(1) and (4) revised.................................22520
    Correctly designated...........................................29480
538.203-71  (d) added; interim......................................3657
    Heading revised; (e) added.....................................52451
    (d) revised....................................................63260
538.272  Added.....................................................52451
552  Technical correction...........................................5484
552.216-73  Revised................................................32384
552.216-74  Added..................................................32385
552.219-9  Added...................................................38934
552.219-16  Added..................................................38935
    Correctly designated...........................................45063
552.219-72  Revised................................................38936
552.219-73  Revised................................................38936
552.219-74  Added..................................................38936
    Corrected......................................................45063
552.225-8  Revised.................................................64857
552.225-9  Revised.................................................64857
552.225-72  Amended................................................64858
552.225-75  Revised................................................64858
552.238-75  Added...................................................3657
    Revised........................................................63260
552.238-76  Added..................................................52452
552.246-70  Amended................................................15134
552.270-4  Amended.................................................52253
552.270-21  Amended................................................52253
552.270-25  Amended................................................52253
552.270-28  Amended................................................52253
552.270-31  Revised................................................52253
552.270-41  Added..................................................52253
570.203  (a)(8)(vi) revised........................................38937
570.702-22  Revised................................................52254
570.702-32  Added..................................................52254
Chapter 6
601  Authority citation revised....................................66750
601.000  Amended...................................................66750
601.101--601.105 (Subpart 601.1)  Added............................66750
601.201-1  Amended.................................................66750
601.301  Revised...................................................66751
601.302  (a) amended...............................................66751
601.303  (c) revised...............................................66751
601.403  Amended...................................................66751
601.404  Amended...................................................66751
601.405  Amended...................................................66751
601.470  Amended...................................................66751

[[Page 404]]

601.471  (a) introductory text amended; (a)(1) and (b) revised.....66751
601.570  Revised...................................................66751
601.602-1  (a) and (b) amended.....................................66751
601.602-3  (b)(1) and (c) amended; (b)(2) revised..................66751
601.602-3-70  Revised..............................................66751
601.603-3  Revised.................................................66752
601.603-70  Revised................................................66752
601.670  Added.....................................................66753
602  Authority citation revised....................................66750
602.101-70  Amended................................................66753
602.201--602.201-70 (Subpart 602.2)  Removed.......................66753
603  Authority citation revised....................................66750
603.104--603.104-11 (Subpart 603.1)  Added.........................66753
603.203  Amended...................................................66754
603.303  (c) amended...............................................66754
603.601  Added.....................................................66754
603.670  Added.....................................................66754
603.704--603.705 (Subpart 603.7)  Added............................66754
604  Authority citation revised....................................66750
604.202  Amended...................................................66754
604.7002  (a) and (b) revised; (c) amended.........................66754
605  Authority citation revised....................................66750
605.202-70  (a), (c)(1) and (2) introductory text amended; (b), 
        (c)(2)(i), (ii) and (d) revised; (e) added.................66754
605.207  (a)(1) added..............................................66755
605.303 (Subpart 605.3)  Added.....................................66755
605.403  Added.....................................................66755
605.502  Revised...................................................66755
606  Authority citation revised....................................66750
606.101-70  Amended................................................66755
606.302-1  Added...................................................66755
606.302-4  Added...................................................66755
606.302-6  Added...................................................66755
606.303-1  Amended.................................................66755
606.304  (a)(2) and (d) added......................................66755
606.304-70  Revised................................................66756
606.370  Added.....................................................66756
606.501  Revised...................................................66756
606.570  Added.....................................................66756
608  Authority citation revised....................................66750
608.402--608.402-70 (Subpart 608.4)  Removed.......................66756
609  Authority citation revised....................................66750
609.202  Amended...................................................66756
609.404  Amended...................................................66756
609.405  Revised...................................................66756
609.405-70  (c) removed; introductory text, (a) and (b) 
        redesignated as (a), (b) and (c); new (a) revised..........66756
610  Added.........................................................66756
613  Authority citation revised....................................66750
613.6-70  Added....................................................66758
613.103-70  (a) and (b) designation removed........................66757
613.505-1  Added...................................................66757
613.505-2  Revised.................................................66758
613.505-70  Added..................................................66758
613.507-70  Amended................................................66758
614  Authority citation revised....................................66750
614.201-7-70  (a)(1) and (d) removed; (a)(2) redesignated as (a); 
        (b) amended; (c) revised...................................66758
614.404-1  Amended.................................................66758
615  Authority citation revised....................................66750
615.106-70  Amended................................................66758
615.403--615.413-2 (Subpart 615.4)  Added..........................66758
615.504--615.506 (Subpart 615.5)  Added............................66758
615.604  Added.....................................................66759
615.607  Amended...................................................66759
615.608  Amended...................................................66759
616  Authority citation revised....................................66750
616.102-70  Revised................................................66759
616.203-4  Amended.................................................66759
616.301-3  Amended.................................................66759
616.306  Amended...................................................66759
616.603-2  Amended.................................................66759
617  Authority citation revised....................................66750
617.102-2  Amended.................................................66759
617.102-3  Added...................................................66759
617.201-70  Amended................................................66759
617.204  Added.....................................................66759
617.207  Removed...................................................66759
617.207-70  Removed................................................66759
617.502  Amended...................................................66759
617.504-70  Added..................................................66759
619  Authority citation revised....................................66750
    Nomenclature change............................................66759
619.201  (c) and (d)(5) amended....................................66759
619.501  Added.....................................................66759
619.506  Added.....................................................66759
619.705-1  Added...................................................66760
619.705-3  Amended.................................................66760
619.705-6-70  (b) amended..........................................66760
619.708-70  Added..................................................66760
619.801  Revised...................................................66760
619.810  Added.....................................................66760
619.812  Added.....................................................66760
619.870  (b) amended...............................................66760
622  Authority citation revised....................................66750

[[Page 405]]

622.401  Added.....................................................66760
622.404-6  (b)(6) added............................................66760
622.406-3  Added...................................................66760
623  Authority citation revised....................................66750
623.302-70 (Subpart 623.3)  Added..................................66760
623.470--623.480 (Subpart 623.4)  Added............................66760
625  Authority citation revised....................................66750
625.102  Revised...................................................66762
625.108  Amended...................................................66762
625.202  Revised...................................................66762
625.203  Added.....................................................66762
625.304  Amended...................................................66762
625.901  Revised...................................................66762
625.1003 (Subpart 625.10)  Removed.................................66762
627  Added.........................................................66763
628  Authority citation revised....................................66750
628.101--628.106-6 (Subpart 628.1)  Added..........................66763
628.203--628.203-7 (Subpart 628.2)  Added..........................66763
628.305--628.307-70 (Subpart 628.3)  Added.........................66763
631  Added.........................................................66764
632  Authority citation revised....................................66750
632.111-632.111-70 (Subpart 632.1)  Removed........................66764
632.402  Existing text designated as (c)(1)(iii); (b) added........66764
632.407  Added.....................................................66764
632.703-3 (Subpart 632.7)  Added...................................66764
632.803 (Subpart 632.8)  Added.....................................66764
632.908  Added.....................................................66764
633  Authority citation revised....................................66750
633.104  Introductory text removed; (a)(1) amended.................66764
633.105  Introductory text removed; (a) and (c) amended............66764
633.214-70  Added..................................................66764
634  Authority citation revised....................................66750
634.001  (b) and (c) amended.......................................66766
634.001-70  Amended................................................66766
634.003  (a) revised; (b) amended..................................66766
634.005  Added.....................................................66766
634.005-6  Added...................................................66766
636  Authority citation revised....................................66750
636.101-70  Amended................................................66766
636.602  Revised...................................................66766
637  Authority citation revised....................................66750
637.104-70  (f) amended............................................66766
637.106  Added.....................................................66766
637.110  Revised...................................................66766
637.204--637.270 (Subpart 637.2)  Removed..........................66766
639  Added.........................................................66766
642  Authority citation revised....................................66750
642.270  Revised...................................................66766
642.271  Amended...................................................66766
643  Authority citation revised....................................66750
643.102-70  (b) revised............................................66767
647  Added.........................................................66767
649  Added.........................................................66767
651  Added.........................................................66767
652  Authority citation revised....................................66750
652.202-70  Removed................................................66767
652.203-70  Added..................................................66767
652.203-71  Added..................................................66767
652.206-70  Added..................................................66767
652.214-70  Removed; new 652.214-70 redesignated from 652.214-71 
        and amended................................................66767
652.214-71  Redesignated as 652.214-70; new 652.214-71 
        redesignated from 652.214-72 and amended...................66767
652.214-72  Redesignated as 652.214-71.............................66767
652.216-70  Amended................................................66768
652.216-71  Added..................................................66768
652.219-70  Added..................................................66768
652.223-70  Added..................................................66768
652.223-71  Added..................................................66768
652.223-72  Added..................................................66768
652.223-73  Added..................................................66769
652.223-74  Added..................................................66769
652.223-75  Added..................................................66769
652.223-76  Added..................................................66769
652.223-77  Added..................................................66769
652.223-78  Added..................................................66769
652.228-71  Added..................................................66770
652.228-72  Added..................................................66770
652.228-73  Added..................................................66770
652.228-74  Added..................................................66771
652.228-75  Added..................................................66771
652.228-76  Added..................................................66771
652.228-77  Added..................................................66771
652.232-70  Revised................................................66771
652.232-71  Revised................................................66772
652.237-70  Revised................................................66772
652.237-71  Added..................................................66772
652.237-72  Added..................................................66772
652.242-70  Amended................................................66772
652.242-72  Amended................................................66772
653  Authority citation revised....................................66750
653.213-70  Revised................................................66773
653.217  Added.....................................................66773
653.217-70  Added..................................................66773
653.219  Added.....................................................66773
653.219-70  Added..................................................66773
653.302  Removed...................................................66773

[[Page 406]]

670 (Subchapter I)  Removed........................................66773

                                  1995

48 CFR
                                                                   60 FR
                                                                    Page
Chapter 3
Chapter 3  Attachment I corrected; CFR correction..................36740
Chapter 5
501.103  (b) revised...............................................42794
501.601  Revised...................................................40108
501.602-1  Removed.................................................40108
501.603  Removed...................................................40108
501.603-3  Removed.................................................40108
501.603-4  Removed.................................................40108
501.603-70  Removed................................................40108
501.700  Removed...................................................54955
501.704  Removed...................................................54955
501.704-70  Removed................................................54955
501.707  Revised...................................................54955
502.101  Amended............................................21467, 54957
503.104-10  (a), (b)(3) and (c) revised............................42794
503.404  (a) revised...............................................42794
503.570-2  Amended.................................................42802
504.800  Amended...................................................42802
504.7001-2  (c) revised; (f) amended...............................54955
505.101  (c) introductory text revised.............................42794
    (b) amended....................................................42802
505.202  (a) introductory text revised; (b)(1) removed; (b)(2) and 
        (3) redesignated as (b)(1) and (2).........................42794
505.203  (b) revised...............................................42794
505.240-70  (b) amended............................................42802
505.303-70  (a)(4) and (b)(1) amended..............................42802
505.503  Amended...................................................42802
506.001  Added.....................................................42794
506.304  Introductory text revised.................................21467
507.100  Removed...................................................42794
507.102  Amended...................................................42802
507.104  (c), (d) and (e) revised..................................54955
507.104  (c), (e) introductory text and (2) revised................42802
508.301--508.370 (Subpart 508.3)  Removed..........................54956
508.7  Heading revised.............................................54956
508.705-70  (b) and (d) revised....................................54956
509.106-70  Removed................................................54956
510.004  (b)(2) amended............................................42802
510.011  (a), (e), (g) and (i) revised; (j) removed................42802
512.104  (b) amended...............................................42803
513  Heading revised...............................................42803
513.106  (c)(2) revised............................................21467
    Revised........................................................42803
513.204  Removed...................................................42803
513.501  Removed...................................................42803
513.505-2  (c) and (d) amended.....................................42803
513.505-3  (a) revised.............................................42803
513.505-70  Revised................................................42803
513.7001  (d)(1), (2) and (4) removed; (b)(3) and (d)(3) 
        redesignated as (b)(4) and (d)(2); new (b)(3) and new 
        (d)(1) added; new (b)(4) and (c) revised...................42803
514.203-1  Heading revised.........................................42803
514.205-1  (a) amended.............................................42803
514.370  Amended...................................................42803
514.402-1  (b) amended.............................................42803
514.406  Redesignated as 514.407...................................42804
514.406-3  Redesignated as 514.407-3...............................42804
514.406-4  Redesignated as 514.407-4...............................42804
514.407  Redesignated as 514.408...................................42803
    Redesignated from 514.406......................................42804
514.407-1  Redesignated as 514.408-1...............................42803
514.407-3  Redesignated from 514.406-3 and revised.................42804
514.407-4  Redesignated from 514.406-4.............................42804
514.407-6  Redesignated as 514.408-6...............................42803
514.407-70  Redesignated as 514.408-70.............................42803
514.407-71  Redesignated as 514.408-71.............................42803
514.407-72  Redesignated as 514.408-72.............................42803
514.408  Redesignated as 514.409...................................42803
    Redesignated from 514.407......................................42803
514.408-1  Redesignated as 514.409-1...............................42803
    Redesignated from 514.407-1; (a), (b) and (c) amended..........42803
    (c) corrected..................................................44387
    (a) revised....................................................54957
514.408-6  Redesignated from 514.407-6.............................42803
514.408-70  Redesignated as 514.409-70.............................42803
    Redesignated from 514.407-70...................................42803
514.408-71  Redesignated from 514.407-71...........................42803

[[Page 407]]

514.408-72  Redesignated from 514.407-72 and revised...............42803
514.409  Redesignated from 514.408.................................42803
514.409-1  Redesignated from 514.408-1.............................42803
514.409-70  Redesignated from 514.408-70...........................42803
515.501  Revised...................................................54956
515.1001  Removed..................................................42804
515.1070  (b), (c) introductory text and (1) amended...............42804
516.301--516.306 (Subpart 516.3)  Removed..........................54956
516.403  Removed...................................................54956
519.001  Revised...................................................39661
519.201  Revised...................................................39661
519.202-2  (c) revised.............................................39661
519.304  Removed...................................................39661
519.502-1  Removed.................................................54956
519.705-2  Revised.................................................42794
519.708  (c) revised; (d)(1) removed; (d)(2) and (3) redesignated 
        as (d)(1) and (2)..........................................42794
523.370  Revised...................................................42804
525.901 (Subpart 525.9)  Added.....................................54957
528.103-2  (a) revised.............................................54956
528.106-1  Removed.................................................54956
528.310  Amended...................................................42804
529.401-70  Revised................................................42804
532.111  (c) and (d) revised.......................................42804
536.302-70  Removed................................................54956
536.570-2  Amended.................................................42804
536.570-4  (c) amended.............................................42804
536.570-5  Amended.................................................42804
536.570-8  Amended.................................................42804
536.570-9  Amended.................................................42804
536.570-13  Amended................................................42804
536.570-14  Amended................................................42804
538.203-71  (a) revised; (f) added.................................19361
541  Added.........................................................54956
542.703 (Subpart 542.7)  Added.....................................54957
543.205  (a) and (b)(2) amended....................................42804
546.403  Introductory text amended.................................42804
546.710  (e) amended...............................................42804
549.111  Revised...................................................54956
552.203-72  Amended................................................42795
552.219-1  Removed.................................................39661
552.225-72  Amended................................................21467
552.238-72  Heading revised; amended...............................19361
552.238-77  Added..................................................19362
    (b)(1) corrected...............................................45528
552.270-1  Introductory text revised...............................42795
552.270-2  Introductory text revised...............................42795
552.270-3  Amended; introductory text revised......................42795
552.270-4  Introductory text revised...............................42795
552.270-5  Introductory text revised...............................42795
552.270-6  Introductory text revised...............................42795
552.270-10  Introductory text revised..............................42795
552.270-11  Introductory text revised..............................42795
552.270-12  Introductory text revised..............................42795
552.270-13  Introductory text revised..............................42795
552.270-15  Introductory text revised..............................42795
552.270-16  Introductory text revised..............................42795
552.270-17  Introductory text revised..............................42795
552.270-18  Introductory text revised..............................42795
552.270-19  Introductory text revised..............................42795
552.270-20  Amended................................................19363
    Introductory text revised......................................42795
552.270-21  Amended; introductory text revised.....................42795
552.270-22  Introductory text revised..............................42796
552.270-23  Removed................................................42796
552.270-24  Removed................................................42796
552.270-25  Introductory text revised..............................42796
552.270-27  Introductory text revised..............................42796
552.270-28  Introductory text revised..............................42796
552.270-30  Introductory text revised..............................42796
552.270-31  Introductory text revised..............................42796
552.270-32  Introductory text revised..............................42796
552.270-33  Introductory text revised..............................42796
552.270-34  Introductory text revised..............................42796
552.270-35  Introductory text revised..............................42796
552.270-36  Introductory text revised..............................42796

[[Page 408]]

552.270-37  Introductory text revised..............................42796
552.270-38  Introductory text revised..............................42796
552.270-39  Introductory text revised..............................42796
552.270-40  Introductory text revised..............................42796
552.270-41  Introductory text revised..............................42796
552.300  Amended...................................................42804
570.102  Amended............................................19363, 42796
570.104  Revised...................................................42796
570.105  Revised...................................................42796
570.201--570.204-5 (Subpart 570.2)  Revised........................42796
570.208-3  Removed.................................................19363
570.301--570.311 (Subpart 570.3)  Revised..........................42797
570.304-5  Revised.................................................19363
570.501  (d) and (e) removed.......................................19363
570.502  (a) (b)(1), (2), (3)(ii) and (iii)(B) revised.............42799
570.503  (a), (b) introductory text and (c) revised................42799
570.504  Revised...................................................42800
570.505  (a) revised...............................................42800
570.602-1  (a) and (b) amended.....................................42800
570.602-2  (c)(3) amended..........................................19363
    (e)(3) and (g) amended.........................................42800
570.701--570.704 (Subpart 570.7)  Revised..........................42800
570.801  Revised...................................................42801
570.802  (c), (e), (f) and (g) removed; (d) redesignated as (c)....19363
    Revised........................................................42801
Chapter 6
601.601--601.603-70  (Subpart) Heading revised.....................39662
601.603-70  (b)(5) and (6) amended.................................39662
602.101-70  Amended................................................39662
605.202-70  Revised................................................39662
606.570  Revised...................................................39662
609.405  (d)(4)(i) amended.........................................39662
610.002-70  (d)(5)(i) amended......................................39662
613  Heading revised...............................................39662
613.103-70  Amended................................................39662
613.403  Redesignated from 613.404 and amended.....................39662
613.404  Redesignated as 613.403...................................39662
613.505-1  Revised.................................................39662
613.505-2  Removed.................................................39663
613.507  Revised...................................................39663
613.507-70  Revised................................................39663
613.601-70  (b) revised............................................39663
616.000  Added.....................................................39663
619.201  (d)(5) amended............................................39663
619.501  (c) amended...............................................39663
625.703  Revised...................................................39663
636.602-5  Amended.................................................39663
637.104-70  (b) and (c) amended....................................39663
653.213  Heading revised...........................................39663
653.213-70  Heading revised; (b) amended...........................39663
653.219-70  Heading revised........................................39663

                                  1996

48 CFR
                                                                   61 FR
                                                                    Page
Chapter 4
Chapter 4  Revised.................................................53646
Chapter 5
501.105  Amended; interim (OMB numbers).............................6164
    Corrected......................................................14033
501.402--501.404 (Subpart 501.4)  Revised..........................51374
504.803  (a)(12) and (25) revised; interim..........................6165
    (a) introductory text corrected................................14033
505.303-70  (a)(1), (b)(1), (2) and (3)(ii) revised.................1150
506.001  Removed...................................................39088
    Regulation at 61 FR 39088 eff. date corrected to 8-19-96.......42190
506.302-1  Amended.................................................39088
    Regulation at 61 FR 39088 eff. date corrected to 8-19-96.......42190
506.303-1  (a) and (b) designation removed.........................39088
    Regulation at 61 FR 39088 eff. date corrected to 8-19-96.......42190
506.303-2  Removed.................................................39088
    Regulation at 61 FR 39088 eff. date corrected to 8-19-96.......42190
506.304  Removed...................................................39088
    Regulation at 61 FR 39088 eff. date corrected to 8-19-96.......42190
507.103  Amended; interim...........................................6165
510  Heading revised; interim.......................................6165
510.001  Redesignated as 511.001; interim...........................6165
510.002  Redesignated as 511.002; interim...........................6165
510.004  Removed; interim...........................................6165
510.004-70  Removed; interim........................................6165
510.004-71  Removed; interim........................................6165
510.007  Removed; interim...........................................6165
510.007-70  Removed; interim........................................6165

[[Page 409]]

510.011  Redesignated as 511.204; interim...........................6165
    (a) corrected..................................................10846
510.070  Removed; interim...........................................6165
510.070-1  Removed; interim.........................................6165
510.070-2  Removed; interim.........................................6165
510.070-3  Removed; interim.........................................6165
510.070-4  Removed; interim.........................................6165
510.071  Removed; interim...........................................6165
511  Heading revised; interim.......................................6165
511.001  Redesignated from 510.001; interim.........................6165
511.002  Redesignated from 510.002 and amended; interim.............6165
511.003  Removed; interim...........................................6165
511.070  Removed; interim...........................................6165
511.103--511.170 (Subpart 511.1)  Added; interim....................6165
511.2 (Subpart 511.2)  Added; interim...............................6166
511.204  Redesignated from 510.011; (c) and (d) removed; (e) 
        through (i) redesignated as (c) through (g); (a), (b) and 
        new (c) through new (g) amended; interim....................6165
511.401  Redesignated from 512.101; interim.........................6166
511.404  Redesignated from 512.104; (a)(2) revised; (a)(3), (4) 
        and (5) redesignated as (a)(4), (5) and (6); (a)(1), new 
        (4), new (5), new (6) and (b) amended; new (a)(3) added; 
        interim.....................................................6166
    (a)(3) corrected...............................................14033
512  Heading revised; interim.......................................6166
512.101--512.104 (Subpart 512.1)  Redesignated as 511.401--511.404 
        (Subpart 511.4); interim....................................6166
512.101  Redesignated as 511.401; interim...........................6166
512.104  Redesignated as 511.404; interim...........................6166
512.203--512.209 (Subpart 512.2)  Added; interim....................6166
512.301--512.302 (Subpart 512.3)  Added; interim....................6166
514.201-70  Revised; interim........................................6167
515.106-70  Revised; interim........................................6167
515.412  Removed; interim...........................................6167
515.414-70  Revised; interim........................................6167
515.804  Heading revised; interim...................................6167
515.804-3  Removed; interim.........................................6167
515.804-6  Revised; interim.........................................6167
    (a) corrected..................................................10846
    (b)(5) corrected...............................................14033
519  Heading revised................................................1150
519.001  Revised....................................................1150
519.201  Revised....................................................1150
519.202-2  Revised..................................................1151
519.202-5  Removed..................................................1151
519.502-70  (a) and (d) revised.....................................1151
519.503  (b) amended................................................1151
519.602-3  (a) and (b) amended......................................1151
519.705--519.708 (Subpart 519.7)  Heading revised...................1151
519.708  Revised....................................................1151
519.803-70  Revised.................................................1151
520  Removed........................................................1151
532.112  Added......................................................1151
532.112-1  Added....................................................1151
532.705-1  Revised..................................................1151
533.104  (a) heading, (c) and (d) revised; (a)(1), (3)(v), (5) 
        introductory text and (b) introductory text amended.........1151
533.105  (a)(1) introductory text amended...........................1152
538  Heading revised; interim.......................................6168
538.000  Removed; interim...........................................6169
538.270  Added; interim.............................................6169
    (d) corrected..................................................10846
538.271  Added; interim.............................................6169
539  Removed; interim...............................................6169
539.000  Removed; interim...........................................6169
543.205  (c) added; interim.........................................6169
546.710  (a)(2) revised; interim....................................6169
547.303-1  (b)(3) amended..........................................39089
    Regulation at 61 FR 39089 eff. date corrected to 8-19-96.......42190
552.209-73  Amended; interim........................................6169
552.210-70  Redesignated as 552.211-71; interim.....................6169
552.210-71  Redesignated as 552.211-72; interim.....................6169
552.210-72  Redesignated as 552.211-79; interim.....................6169
552.210-73  Redesignated as 552.211-80; interim.....................6169
552.210-74  Redesignated as 552.211-70; interim.....................6169
552.210-75  Redesignated as 552.211-73; interim.....................6169
552.210-76  Redesignated as 552.211-74; interim.....................6170
552.210-77  Redesignated as 552.211-75; interim.....................6170
552.210-78  Redesignated as 552.211-76; interim.....................6170
552.210-79  Redesignated as 552.211-77; interim.....................6170

[[Page 410]]

552.211-1  Redesignated from 552.212-1 and amended; interim.........6170
552.211-70  Removed; new 552.211-70 redesignated from 552.210-74 
        and amended; interim........................................6169
552.211-71  Redesignated from 552.210-70 and amended; interim.......6169
552.211-72  Redesignated from 552.210-71 and amended; interim.......6169
552.211-73  Redesignated from 552.210-75 and amended; interim.......6169
552.211-74  Redesignated from 552.210-76 and amended; interim.......6170
552.211-75  Redesignated from 552.210-77 and amended; interim.......6170
552.211-76  Redesignated from 552.210-78 and amended; interim.......6170
552.211-77  Redesignated from 552.210-79 and amended; interim.......6170
552.211-78  Added; interim..........................................6170
552.211-79  Redesignated from 552.210-72 and amended; interim.......6169
552.211-80  Redesignated from 552.210-73 and amended; interim.......6169
552.211-81  Redesignated from 552.212-70 and amended; interim.......6170
552.211-82  Redesignated from 552.212-71 and amended; interim.......6170
    Correctly designated...........................................14033
552.211-83  Redesignated from 552.212-72 and amended; interim.......6170
552.211-84  Redesignated from 552.212-74 and amended; interim.......6170
552.212-1  Redesignated as 552.211-1; interim.......................6170
552.212-70  Redesignated as 552.211-81; new 552.212-70 added; 
        interim.....................................................6170
552.212-71  Redesignated as 552.211-82; interim.....................6170
    Added; interim..................................................6171
    Corrected......................................................10846
552.212-72  Redesignated as 552.211-83; interim.....................6170
    Added; interim..................................................6171
552.212-73  Added; interim..........................................6171
552.212-74  Redesignated as 552.211-84; interim.....................6170
552.215-70  Amended; interim........................................6172
552.215-71  Added; interim..........................................6172
552.215-72  Added; interim..........................................6172
552.216-71  Amended; interim........................................6172
    Corrected......................................................10846
552.219-9  Removed..................................................1152
552.219-16  Removed.................................................1152
552.219-72  Revised.................................................1152
552.219-73  Amended.................................................1152
552.219-74  Amended..........................................1152, 39089
    Regulation at 61 FR 39089 eff. date corrected to 8-19-96.......42190
    Corrected......................................................42462
552.238-74  Amended; interim........................................6172
552.243-72  Added; interim..........................................6172
    Corrected......................................................10846
552.246-73  Amended; interim........................................6173
552.253-70  Removed; interim........................................6173
570.106  (c) added; interim........................................24721
570.303  (a)(7) revised; (a)(8) removed; (a)(9) and (10) 
        redesignated as (a)(8) and (9); interim....................24721
570.308-2  (c) amended; interim.....................................6173
570.602-2  (c)(3) and (d) amended; interim..........................6173

                                  1997

48 CFR
                                                                   62 FR
                                                                    Page
Chapter 5
Chapter 5  Compliance guide........................................44526
501.105  Regulation at 61 FR 6164 confirmed........................44521
504.803  Regulation at 61 FR 6165 confirmed........................44521
507.103  Regulation at 61 FR 6165 confirmed........................44521
510  Regulation at 61 FR 6165 confirmed............................44251
510.001  Regulation at 61 FR 6165 confirmed........................44521
510.002  Regulation at 61 FR 6165 confirmed........................44251
510.004  Regulation at 61 FR 6165 confirmed........................44521
510.004-70  Regulation at 61 FR 6165 confirmed.....................44521
510.004-71  Regulation at 61 FR 6165 confirmed.....................44521

[[Page 411]]

510.007  Regulation at 61 FR 6165 confirmed........................44521
510.007-70  Regulation at 61 FR 6165 confirmed.....................44521
510.011  Regulation at 61 FR 6165 confirmed........................44251
510.070  Regulation at 61 FR 6165 confirmed........................44521
510.070-1  Regulation at 61 FR 6165 confirmed......................44521
510.070-2  Regulation at 61 FR 6165 confirmed......................44521
510.070-3  Regulation at 61 FR 6165 confirmed......................44521
510.070-4  Regulation at 61 FR 6165 confirmed......................44521
510.071  Regulation at 61 FR 6165 confirmed........................44521
511  Regulation at 61 FR 6165 confirmed............................44521
511.001  Regulation at 61 FR 6165 confirmed........................44251
511.002  Regulation at 61 FR 6165 confirmed........................44251
511.003  Regulation at 61 FR 6165 confirmed........................44521
511.070  Regulation at 61 FR 6165 confirmed........................44521
511.103--511.170 (Subpart 511.1)  Regulation at 61 FR 6165 
        confirmed..................................................44521
511.204 (Subpart 511.2)  Regulation at 61 FR 6166 confirmed........44251
511.204  Regulation at 61 FR 6165 confirmed........................44251
511.401--511.404 (Subpart 511.4)  Regulation at 61 FR 6166 
        confirmed..................................................44251
511.401  Regulation at 61 FR 6166 confirmed........................44521
511.404  Regulation at 61 FR 6166 confirmed........................44521
512  Regulation at 61 FR 6166 confirmed............................44521
512.104--512.104 (Subpart 512.1)  Regulation at 61 FR 6166 
        confirmed..................................................44521
512.101  Regulation at 61 FR 6166 confirmed........................44521
512.104  Regulation at 61 FR 6166 confirmed........................44521
512.201--512.209 (Subpart 512.2)  Regulation at 61 FR 6166 
        confirmed..................................................44521
512.301--512.303 (Subpart 512.3)  Regulation at 61 FR 6166 
        confirmed..................................................44521
514.201-70  Regulation at 61 FR 6167 confirmed.....................44521
515.106-70  Revised................................................44521
515.412  Regulation at 61 FR 6167 confirmed........................44521
515.414-70  Regulation at 61 FR 6166 confirmed.....................44521
515.804  Regulation at 61 FR 6167 confirmed........................44521
515.804-3  Regulation at 61 FR 6167 confirmed......................44521
515.804-6  Regulation at 61 FR 6167 confirmed......................44521
    Revised........................................................44522
538  Regulation at 61 FR 6168 confirmed............................44521
538.000  Regulation at 61 FR 6169 confirmed........................44521
538.270  Regulation at 61 FR 6169 confirmed........................44521
    Revised........................................................44523
538.271  Regulation at 61 FR 6169 confirmed........................44521
    (a) revised....................................................44524
539  Regulation at 61 FR 6169 confirmed............................44521
539.000  Regulation at 61 FR 6169 confirmed........................44521
543.205  Regulation at 61 FR 6169 confirmed........................44521
    (c) revised....................................................44524
546.710  Regulation at 61 FR 6169 confirmed........................44521
552.209-73  Regulation at 61 FR 6169 confirmed.....................44521
552.210-70  Regulation at 61 FR 6169 confirmed.....................44521
552.210-71  Regulation at 61 FR 6169 confirmed.....................44521
552.210-72  Regulation at 61 FR 6169 confirmed.....................44521
552.210-73  Regulation at 61 FR 6169 confirmed.....................44521
552.210-74  Regulation at 61 FR 6169 confirmed.....................44521
552.210-75  Regulation at 61 FR 6169 confirmed.....................44521
552.210-76  Regulation at 61 FR 6170 confirmed.....................44521
552.210-77  Regulation at 61 FR 6170 confirmed.....................44521
552.210-78  Regulation at 61 FR 6170 confirmed.....................44521

[[Page 412]]

552.210-79  Regulation at 61 FR 6170 confirmed.....................44521
552.211-1  Regulation at 61 FR 6170 confirmed......................44521
552.211-71  Regulation at 61 FR 6169 confirmed.....................44521
552.211-72  Regulation at 61 FR 6169 confirmed.....................44521
552.211-73  Regulation at 61 FR 6169 confirmed.....................44521
552.211-74  Regulation at 61 FR 6170 confirmed.....................44521
552.211-75  Regulation at 61 FR 6170 confirmed.....................44521
552.211-76  Regulation at 61 FR 6170 confirmed.....................44521
552.211-77  Regulation at 61 FR 6170 confirmed.....................44521
552.211-78  Regulation at 61 FR 6170 confirmed.....................44521
552.211-79  Regulation at 61 FR 6169 confirmed.....................44521
552.211-80  Regulation at 61 FR 6169 confirmed.....................44521
552.211-81  Regulation at 61 FR 6170 confirmed.....................44521
552.211-82  Regulation at 61 FR 6170 confirmed.....................44521
552.211-83  Regulation at 61 FR 6170 confirmed.....................44521
552.211-84  Regulation at 61 FR 6170 confirmed.....................44521
552.212-1  Regulation at 61 FR 6170 confirmed......................44521
552.212-70  Regulation at 61 FR 6170 confirmed.....................44521
    Revised........................................................44524
552.212-71  Regulations at 61 FR 6170 and 6171 confirmed...........44521
    Amended........................................................44524
552.212-72  Regulations at 61 FR 6170 and 6171 confirmed...........44521
552.212-73  Regulation at 61 FR 6171 confirmed.....................44521
    Revised........................................................44524
552.212-74  Regulation at 61 FR 6170 confirmed.....................44521
552.215-70  Regulation at 61 FR 6172 confirmed.....................44521
552.215-71  Regulation at 61 FR 6172 confirmed.....................44521
    Revised........................................................44525
552.215-72  Regulation at 61 FR 6172 confirmed.....................44251
    Revised........................................................44525
552.216-71  Regulation at 61 FR 6172 confirmed.....................44521
552.238-72  Amended................................................38476
552.238-74  Regulation at 61 FR 6172 confirmed.....................44521
552.238-77  Amended................................................38476
552.243-72  Regulation at 61 FR 6172 confirmed.....................44521
    Amended........................................................44525
552.246-73  Regulation at 61 FR 6173 confirmed.....................44521
552.253-70  Regulation at 61 FR 6173 confirmed.....................44521
552.308-2  Regulation at 61 FR 6173 confirmed......................44521
552.602-2  Regulation at 61 FR 6173 confirmed......................44521
570.106  (c) introductory text, (1), (2) and (3) revised............5166
570.308-2  (e) revised.............................................44525

                                  1998

48 CFR
                                                                   63 FR
                                                                    Page
Chapter 4
Chapter 4  Policy statement.........................................9158
401  Effective date confirmation...................................39239
401.170  Added.....................................................26994
402  Effective date confirmation...................................39239
402.101  Amended...................................................26994
403  Effective date confirmation...................................39239
403.104-5  Removed.................................................26995
403.104-11  Redesignated as 403.104-10.............................26995
403.104-10  Redesignated from 403.104-11; heading and (b) revised 
                                                                   26995
403.503  (b)(4) amended............................................26995
408  Nomenclature change...........................................26995
    Effective date confirmation....................................39239
409  Effective date confirmation...................................39239
409.403  Revised...................................................26995
411  Effective date confirmation...................................39239
411.171  Revised...................................................26995
411.404  Revised...................................................26995
416  Effective date confirmation...................................39239
416.404  Redesignated as 416.405...................................26995
416.404-2  Redesignated as 416.405-2...............................26995

[[Page 413]]

416.405  Redesignated as 416.406; new 416.405 redesignated from 
        416.404....................................................26995
416.405-2  Redesignated from 416.404-2.............................26995
416.406  Redesignated from 416.405.................................26995
419  Effective date confirmation...................................39239
419.201-73  (b) revised............................................26995
419.602-3  Revised.................................................26995
422  Effective date confirmation...................................39239
422.608  Removed...................................................26995
422.608-4  Removed.................................................26995
424  Effective date confirmation...................................39239
424.202  Redesignated as 424.203...................................26995
424.203  Redesignated from 424.202.................................26995
425  Effective date confirmation...................................39239
425.202  Revised...................................................26995
425.203  Removed...................................................26995
425.204  Removed...................................................26995
426  Added.........................................................26997
432  Effective date confirmation...................................39239
432.111  Amended...................................................26995
434  Effective date confirmation...................................39239
434.001  Introductory text amended.................................26995
436  Effective date confirmation...................................39239
436.213  Added.....................................................26995
436.213-2  Added...................................................26995
436.302 (Subpart 436.3)  Removed...................................26995
436.575  Revised...................................................26996
452  Effective date confirmation...................................39239
452.211-1  Redesignated as 452.211-70..............................26996
452.211-2  Redesignated as 452.211-71..............................26996
452.211-3  Redesignated as 452.211-72..............................26996
452.211-4  Redesignated as 452.211-73..............................26996
452.211-5  Redesignated as 452.211-74..............................26996
452.211-6  Redesignated as 452.211-75..............................26996
452.211-70  Redesignated from 452.211-1............................26996
452.211-71  Redesignated from 452.211-2............................26996
452.211-72  Redesignated from 452.211-3............................26996
452.211-73  Redesignated from 452.211-4............................26996
452.211-74  Redesignated from 452.211-5............................26996
452.211-75  Redesignated from 452.211-6............................26996
452.226-70  Added..................................................26998
452.226-71  Added..................................................26998
452.226-72  Added..................................................26998
452.232-1  Redesignated as 452.232-70..............................26996
452.232-70  Redesignated from 452.232-1............................26996
Chapter 5
Chapter 5  Small entity compliance guide...........................12969
501.103  (b) amended...............................................19194
503.104-10  Revised; interim.......................................18844
503.404  (a) and (b) designation removed; interim..................18844
515.106-70  (a) revised; interim...................................18844
515.406-1  (b) revised.............................................19194
532  Technical correction..........................................39934
532.902  Added; interim............................................12966
    Regulation at 63 FR 12966 confirmed; amended...................38330
532.905  (c) added; interim........................................12966
    Regulation at 63 FR 12966 confirmed; (c)(2) revised............38330
532.908  (a) revised; interim......................................12966
    Regulation at 63 FR 12966 confirmed............................38330
538.203-71  (a) revised............................................19194
552  Technical correction..........................................39934
552.203-71  Removed; interim.......................................18844
552.203-72  Removed; interim.......................................18844
552.203-73  Introductory text revised; interim.....................18844
552.212-71  Amended; interim.......................................12967
    Regulation at 63 FR 12967 confirmed............................38330
552.232-25  Added; interim.........................................12967
    Regulation at 63 FR 12967 confirmed............................38330
    Amended........................................................38331
552.232-70  Revised; interim.......................................12969
    Regulation at 63 FR 12969 confirmed............................38330
    Amended........................................................38331
552.238-72  Revised................................................19194
552.238-74  Amended................................................38331
552.238-77  Revised................................................19195

[[Page 414]]

552.270-1  Revised; interim........................................18844
552.270-2  Removed; interim........................................18846
552.270-3  Removed; interim........................................18846
552.270-4  Introductory text revised; interim......................18846
552.270-5  Removed; interim........................................18846
552.270-6  Introductory text revised; interim......................18846
552.270-20  Amended; interim.......................................18846
570.107  Added; interim............................................18846
570.204-4  Revised; interim........................................18846
570.303  (a)(7)(i) and (8) revised; interim........................18846
570.305  Revised; interim..........................................18846
570.306  Removed; interim..........................................18846
570.307  Revised; interim..........................................18847
570.308-1  (b) removed; (c) redesignated as (b); interim...........18847
570.308-2  Revised; interim........................................18847
570.308-3  Revised; interim........................................18847
570.309  Revised; interim..........................................18847
570.310  Revised; interim..........................................18847
570.401  Revised; interim..........................................18847
570.602-2  (c)(3), (d), (e)(3) and (f)(3) revised; interim.........18847
570.701  (c), (d), (f), (g), (h), (j) and (k) revised; interim.....18847
570.702  Revised; interim..........................................18848
570.703  (a)(25) removed; (a)(26) redesignated as (a)(25)..........18848
570.704  Revised; interim..........................................18848

                                  1999

48 CFR
                                                                   64 FR
                                                                    Page
Chapter 4
401.106  Amended; eff. 11-29-99....................................52674
413  Revised; eff. 10-22-99........................................45895
415  Revised; eff. 11-29-99........................................52674
415.207  (b) corrected.............................................54963
437.204  Added; eff. 11-29-99......................................52675
452.215-71  (c) introductory text and (1) revised; Alternates I 
        and II removed; eff. 11-29-99..............................52675
452.215-72  Amended; eff. 11-29-99.................................52675
452.215-73  Amended; eff. 11-29-99.................................52675
453.213  Amended; eff. 10-22-99....................................45895
Chapter 5
Chapter  5 Revised.................................................37202
511.204  (c) revised; interim.......................................4789
516.505  (a) revised; interim.......................................4789
542.302  (b)(5) revised; interim....................................4789
552  Authority citation correctly revised..........................48718
552.216-70  (c) corrected..........................................49844
552.216-73  Amended; interim........................................4789
552.219-72  Revised................................................15306
552.219-73  Revised................................................15306
552.219-74  Revised................................................15307
552.238-72  Amended; interim........................................4789
552.238-76  Amended; interim........................................4789
552.243-72  Amended; interim........................................4789
553  Authority citation correctly revised..........................48718
570  Authority citation correctly revised..........................48718
570.502-2  (e) correctly designated................................49844
Chapter 6
601.105  Redesignated as 601.106; new 601.105 added................43619
    Added..........................................................43620
601.105-3  Added...................................................43620
601.106  Redesignated from 601.105.................................43619
    Revised........................................................43620
601.301  (a)(1) designation and (2) removed........................43620
601.302  (a) amended...............................................43620
601.303  (c) amended...............................................43620
601.471  Removed...................................................43620
601.601--601.670 (Subpart 601.6)  Heading revised..................43620
601.602-3  Removed.................................................43620
601.602-3-70  Removed..............................................43620
601.603-3  (a) heading and (d) added; (a) amended; (b) revised.....43620
601.603-70  (a)(1) introductory text, (2), (3), (7), (8), (b) 
        introductory text and (1) through (6) amended; (a)(3) 
        heading and (9) revised; (b)(7) added......................43620
601.670  Removed...................................................43620
602.101-70  Amended................................................43620
603.104--603.104-10 (Subpart 603.1)   Revised......................43620
603.203  Removed...................................................43621
603.303 (Subpart 603.3)  Removed...................................43621
603.405  Added.....................................................43621
603.408  Removed...................................................43621
603.408-1  Removed.................................................43621
603.670  Removed...................................................43621
603.905--603.906 (Subpart 603.9)  Added............................43621
604.202 (Subpart 604.2)  Removed...................................43621

[[Page 415]]

604.404--604.404-70 (Subpart 604.4)  Removed.......................43621
604.502 (Subpart 604.5)  Added.....................................43621
604.7001--604.7002 (Subpart 604.70)  Removed.......................43621
605.202-70  (a) amended............................................43621
605.207  Removed...................................................43621
605.303  (a) amended...............................................43621
606.101--606.101-70 (Subpart 606.1)  Removed.......................43621
606.302-6  (c)(1) introductory text and (c)(1)(vi) amended.........43621
606.304  (a)(2) amended............................................43621
606.501  (b) amended...............................................43622
606.570  Revised...................................................43622
608  Removed.......................................................43622
609.206  Added.....................................................43622
609.206-1  Added...................................................43622
609.404  Heading revised...........................................43622
609.405  (d)(4)(i) and (ii) revised................................43622
609.406-3  (a)(1) and (b)(7) revised...............................43622
609.5  Heading revised.............................................43622
610  Removed.......................................................43622
611  Added.........................................................43622
613  Revised.......................................................43623
614.201--614.201-70 (Subpart 614.2)  Revised.......................43623
614.404-1  (f) added...............................................43623
614.406  Redesignated as 614.407...................................43623
614.406-3  Redesignated as 614.407-3...............................43623
614.406-4  Redesignated as 614.407-4...............................43623
614.407  Redesignated from 614.406.................................43623
614.407-3  Redesignated from 614.406-3 and amended.................43623
614.407-4  Redesignated from 614.406-4 and amended.................43623
615  Revised.......................................................43623
616.102--616.102-70 (Subpart 616.1)  Removed.......................43624
616.301-3--616.306 (Subpart 616.3)  Removed........................43624
616.505  Redesignated as 616.506; new 616.505 added................43624
616.506  Redesignated from 616.505; heading revised................43624
616.505-70  Redesignated as 616.506-70.............................43624
616.506-70  Redesignated from 616.505-70...........................43624
616.603--616.603-2 (Subpart 616.6)  Removed........................43624
617.104--617.108 (Subpart 617.1)  Revised..........................43624
617.502  Removed...................................................43624
617.503  Added.....................................................43624
617.504-70  (a) amended............................................43624
619  Heading revised...............................................43624
619.201  (d)(5) amended; (d)(18) revised...........................43624
619.501  Amended...................................................43624
619.505  Heading revised...........................................43624
619.705--619.708-70 (Subpart 619.7)  Heading revised...............43624
619.705-3  Revised.................................................43624
619.800--619.812 (Subpart 619.8)  Revised..........................43624
622.401  Removed...................................................43626
622.406-3  Removed.................................................43626
622.803  Added.....................................................43626
622.1303--622.1308 (Subpart 622.13)  Heading revised...............43626
622.1403--622.1402 (Subpart 622.14)  Heading revised...............43626
623.400--623.404 (Subpart 623.4)  Revised..........................43626
625.901--625.903 (Subpart 625.9)  Removed..........................43626
625.7001--625.7002 (Subpart 625.70)  Added.........................43626
626  Added.........................................................43627
628.305  (b) introductory text amended; (b)(1), (2), and (3) 
        removed....................................................43627
628.306  Revised...................................................43627
628.307  Revised...................................................43627
628.307-70  Removed................................................43627
629.402  Added.....................................................43627
629.402-1  Added...................................................43627
629.402-1-70  Added................................................43627
630  Removed.......................................................43627
631.205--231.205-6 (Subpart 631.2)  Added..........................43627
632.006  Added.....................................................43627
632.006-1  Added...................................................43627
632.006-2  Added...................................................43627
632.006-4  Added...................................................43627
632.114 (Subpart 632.1)  Added.....................................43627
632.201 (Subpart 632.2)  Added.....................................43627
632.404  Added.....................................................43627
632.702--632.705-70 (Subpart 632.7)  Revised.......................43628
632.803  (b) amended...............................................43628
633.102  Amended...................................................43628
633.103  Revised...................................................43628
633.104  Revised...................................................43628
633.105  Removed...................................................43628
633.211  Removed...................................................43628

[[Page 416]]

633.214-70  (c) introductory text and (c)(2), (4), (5), and 
        (6)(iii) amended...........................................43628
633.270-1  Amended.................................................43628
633.270-2  Amended.................................................43628
633.270-3  Amended.................................................43628
634.001  Removed...................................................43628
634.001-70  Removed................................................43628
634.002  Removed...................................................43628
634.003  (a) amended...............................................43628
634.005-6  Amended.................................................43628
636.101-70  Amended................................................43628
636.513 (Subpart 636.5)  Added.....................................43628
636.602-1  Added...................................................43628
637.104-70  Heading revised; (g) and (h) amended; (i) added........43629
637.106  Removed...................................................43629
637.110  (c) amended...............................................43629
637.204 (Subpart 637.2)  Added.....................................43629
639  Removed.......................................................43629
641  Added.........................................................43629
642  Heading revised...............................................43629
642.270--642.271 (Subpart 642.2)  Heading revised..................43629
642.271  Revised...................................................43629
642.703--642.703-2 (Subpart 642.7)  Added..........................43629
643.102-70  (a) designation and (b) removed........................43629
643.104  Added.....................................................43629
643.104-70  Added..................................................43629
644  Added.........................................................43629
645.403 (Subpart 645.4)  Added.....................................43629
646  Removed.......................................................43629
647.207--647.207-7 (Subpart 647.2)  Added..........................43629
649.111  Removed...................................................43629
652.203-70  Removed................................................43629
652.203-71  Removed................................................43629
652.204-70  Removed................................................43629
652.204-71  Removed................................................43629
652.206-70  Revised................................................43629
652.214-70  Removed................................................43630
652.214-71  Removed................................................43630
652.216-70  Introductory text revised..............................43630
652.216-71  Revised................................................43630
652.219-71  Added..................................................43630
652.223-70  Removed................................................43631
652.223-71  Removed................................................43631
652.223-72  Removed................................................43631
652.223-73  Removed................................................43631
652.223-74  Removed................................................43631
652.223-75  Removed................................................43631
652.223-76  Removed................................................43631
652.223-77  Removed................................................43631
652.223-78  Removed................................................43631
652.225-70  Added..................................................43631
652.225-71  Added..................................................43631
652.226-70  Added..................................................43631
652.228-70  Introductory text revised..............................43632
652.228-71  Revised................................................43632
652.228-72  Removed................................................43632
652.228-73  Removed................................................43632
652.228-74  Revised................................................43632
652.228-75  Removed................................................43632
652.228-76  Revised................................................43632
652.228-77  Removed................................................43632
652.229-70  Introductory text revised..............................43632
652.229-71  Added..................................................43633
652.232-70  Amended................................................43633
652.232-71  Amended................................................43633
652.232-72  Added..................................................43633
652.236-70  Added..................................................43633
652.237-71  Amended................................................43634
652.237-72  Amended................................................43634
652.242-70  Amended................................................43634
652.242-71  Introductory text revised..............................43634
652.242-72  Introductory text revised..............................43634
652.242-73  Added..................................................43634
652.243-70  Added..................................................43634
652.246-70  Removed................................................43634
653.213-70  Removed................................................43634
653.219  Heading revised...........................................43634
653.219-70  Revised................................................43634

                                  2000

48 CFR
                                                                   65 FR
                                                                    Page
Chapter 5
Chapter  5 Regulation at 64 FR 37202 confirmed.....................11247
501.106  Amended...................................................41378
511.104  Redesignated from 511.170; heading revised................41378
511.104-70  Redesignated from 511.170-3; (c) and (d) removed; new 
        (c) added..................................................41378
511.170  Redesignated as 511.104...................................41378
511.170-3  Redesignated as 511.104-70..............................41378
512.301  (a)(3) revised............................................41378
513.302-70  (a) revised............................................11247
515.408  (d) revised...............................................11247
525.105  Removed...................................................41379
525.105-70  Removed................................................41379
525.109  Removed...................................................41379

[[Page 417]]

525.402--525.408 (Subpart 525.4)  Removed..........................41379
525.570 (Subpart 525.5)  Added.....................................41379
525.1101 (Subpart 525.11)  Added...................................41379
532.908  (c) added.................................................41379
532.7002  Revised..................................................11247
532.7003  Revised..................................................11247
536.602--536.602-1 (Subpart 536.6)  Added..........................11247
537.110  Revised...................................................41379
546.710  (b) revised; (c) removed; (d) and (e) redesignated as (c) 
        and (d)....................................................11248
552.211-70  Removed................................................41379
552.212-71  Amended................................................41379
552.212-72  Amended................................................41379
552.225-8  Removed.................................................41379
552.225-9  Removed.................................................41379
552.225-70  Introductory text revised..............................41379
552.232-76  Amended................................................11248
552.232-77  Revised................................................11248
552.232-78  Added..................................................41379
552.233-70  Amended................................................11248
552.243-72  Amended................................................41379
552.246-73  Revised................................................11248
552.246-74  Removed................................................11248
552.246-75  Introductory text revised..............................11249
552.246-76  Introductory text revised..............................11249
552.247-71  Amended................................................11249

                                  2001

  (Regulations published from January 1, 2001, through October 1, 2001)

48 CFR
                                                                   66 FR
                                                                    Page
Chapter 3
Chapter 3  Revised..................................................4220
Chapter 4
419.508  Amended; eff. 11-26-01....................................49317
442.1502  Revised; eff. 11-30-01...................................49867
452.219-70  Amended; eff. 11-26-01.................................49317


                                  
