[Title 48 CFR ]
[Code of Federal Regulations (annual edition) - October 1, 1997 Edition]
[From the U.S. Government Publishing Office]


[[Page 1]]

          48



          Federal Acquisition Regulations System



          CHAPTERS 7 TO 14

                         Revised as of October 1, 1997

          CONTAINING
          A CODIFICATION OF DOCUMENTS
          OF GENERAL APPLICABILITY
          AND FUTURE EFFECT
          AS OF OCTOBER 1, 1997

          With Ancillaries
          Published by
          the Office of the Federal Register
          National Archives and Records
          Administration
          as a Special Edition of
          the Federal Register



[[Page ii]]

                                      




                     U.S. GOVERNMENT PRINTING OFFICE
                            WASHINGTON : 1997



               For sale by U.S. Government Printing Office
 Superintendent of Documents, Mail Stop: SSOP, Washington, DC 20402-9328



[[Page iii]]




                            Table of Contents



                                                                    Page
  Explanation.................................................       v

  Title 48:
    Chapter 7--Agency for International Development...........       3
    Chapter 8--Department of Veterans Affairs.................     135
    Chapter 9--Department of Energy...........................     261
    Chapter 10--Department of the Treasury....................     511
    Chapter 12--Department of Transportation..................     515
    Chapter 13--Department of Commerce........................     587
    Chapter 14--Department of the Interior....................     619
  Finding Aids:
    Table of CFR Titles and Chapters..........................     637
    Alphabetical List of Agencies Appearing in the CFR........     653
    List of CFR Sections Affected.............................     663



[[Page iv]]


      


--------------------------------------------------------------

   Cite this Code:  CFR

   To cite the regulations in this volume use title, part and
   section number. Thus,  48 CFR 701.105 refers to title 48,
   part 701, section 105.

--------------------------------------------------------------


[[Page v]]



                               EXPLANATION

    The Code of Federal Regulations is a codification of the general and 
permanent rules published in the Federal Register by the Executive 
departments and agencies of the Federal Government. The Code is divided 
into 50 titles which represent broad areas subject to Federal 
regulation. Each title is divided into chapters which usually bear the 
name of the issuing agency. Each chapter is further subdivided into 
parts covering specific regulatory areas.
    Each volume of the Code is revised at least once each calendar year 
and issued on a quarterly basis approximately as follows:

Title 1 through Title 16.................................as of January 1
Title 17 through Title 27..................................as of April 1
Title 28 through Title 41...................................as of July 1
Title 42 through Title 50................................as of October 1
    The appropriate revision date is printed on the cover of each 
volume.

LEGAL STATUS

    The contents of the Federal Register are required to be judicially 
noticed (44 U.S.C. 1507). The Code of Federal Regulations is prima facie 
evidence of the text of the original documents (44 U.S.C. 1510).

HOW TO USE THE CODE OF FEDERAL REGULATIONS

    The Code of Federal Regulations is kept up to date by the individual 
issues of the Federal Register. These two publications must be used 
together to determine the latest version of any given rule.
    To determine whether a Code volume has been amended since its 
revision date (in this case, October 1, 1997), consult the ``List of CFR 
Sections Affected (LSA),'' which is issued monthly, and the ``Cumulative 
List of Parts Affected,'' which appears in the Reader Aids section of 
the daily Federal Register. These two lists will identify the Federal 
Register page number of the latest amendment of any given rule.

EFFECTIVE AND EXPIRATION DATES

    Each volume of the Code contains amendments published in the Federal 
Register since the last revision of that volume of the Code. Source 
citations for the regulations are referred to by volume number and page 
number of the Federal Register and date of publication. Publication 
dates and effective dates are usually not the same and care must be 
exercised by the user in determining the actual effective date. In 
instances where the effective date is beyond the cut-off date for the 
Code a note has been inserted to reflect the future effective date. In 
those instances where a regulation published in the Federal Register 
states a date certain for expiration, an appropriate note will be 
inserted following the text.

OMB CONTROL NUMBERS

    The Paperwork Reduction Act of 1980 (Pub. L. 96-511) requires 
Federal agencies to display an OMB control number with their information 
collection request.

[[Page vi]]

Many agencies have begun publishing numerous OMB control numbers as 
amendments to existing regulations in the CFR. These OMB numbers are 
placed as close as possible to the applicable recordkeeping or reporting 
requirements.

OBSOLETE PROVISIONS

    Provisions that become obsolete before the revision date stated on 
the cover of each volume are not carried. Code users may find the text 
of provisions in effect on a given date in the past by using the 
appropriate numerical list of sections affected. For the period before 
January 1, 1986, consult either the List of CFR Sections Affected, 1949-
1963, 1964-1972, or 1973-1985, published in seven separate volumes. For 
the period beginning January 1, 1986, a ``List of CFR Sections 
Affected'' is published at the end of each CFR volume.

CFR INDEXES AND TABULAR GUIDES

    A subject index to the Code of Federal Regulations is contained in a 
separate volume, revised annually as of January 1, entitled CFR Index 
and Finding Aids. This volume contains the Parallel Table of Statutory 
Authorities and Agency Rules (Table I), and Acts Requiring Publication 
in the Federal Register (Table II). A list of CFR titles, chapters, and 
parts and an alphabetical list of agencies publishing in the CFR are 
also included in this volume.
    An index to the text of ``Title 3--The President'' is carried within 
that volume.
    The Federal Register Index is issued monthly in cumulative form. 
This index is based on a consolidation of the ``Contents'' entries in 
the daily Federal Register.
    A List of CFR Sections Affected (LSA) is published monthly, keyed to 
the revision dates of the 50 CFR titles.

REPUBLICATION OF MATERIAL

    There are no restrictions on the republication of material appearing 
in the Code of Federal Regulations.

INQUIRIES

    For a legal interpretation or explanation of any regulation in this 
volume, contact the issuing agency. The issuing agency's name appears at 
the top of odd-numbered pages.
    For inquiries concerning CFR reference assistance, call 202-523-5227 
or write to the Director, Office of the Federal Register, National 
Archives and Records Administration, Washington, DC 20408.

SALES

    The Government Printing Office (GPO) processes all sales and 
distribution of the CFR. For payment by credit card, call 202-512-1800, 
M-F 8 a.m. to 4 p.m. e.s.t. or fax your order to 202-512-2233, 24 hours 
a day. For payment by check, write to the Superintendent of Documents, 
Attn: New Orders, P.O. Box 371954, Pittsburgh, PA 15250-7954. For GPO 
Customer Service call 202-512-1803.

                              Raymond A. Mosley,
                                    Director,
                          Office of the Federal Register.

October 1, 1997.



[[Page vii]]



                               THIS TITLE

    Title 48--Federal Acquisition Regulations System is composed of 
eight volumes. The chapters in these volumes are arranged as follows: 
Chapter 1 (parts 1 to 51), chapter 1 (parts 52 to 99), chapter 2 (parts 
201 to 299), chapters 3 to 6, chapters 7 to 14, chapters 15 to 28 and 
chapter 29 to end. The contents of these volumes represent all current 
regulations codified under this title of the CFR as of October 1, 1997.

    The Federal acquisition regulations in chapter 1 are those 
government-wide acquisition regulations jointly issued by the General 
Services Administration, the Department of Defense, and the National 
Aeronautics and Space Administration. Chapters 2 through 99 are 
acquisition regulations issued by individual government agencies. Parts 
1 to 69 in each of chapters 2 through 99 are reserved for agency 
regulations implementing the Federal acquisition regulations in chapter 
1 and are numerically keyed to them. Parts 70 to 99 in chapters 2 
through 99 contain agency regulations supplementing the Federal 
acquisition regulations.

    The OMB control numbers for the Federal Acquisition Regulations 
System appear in section 1.106 of chapter 1. For the convenience of the 
user section 1.106 is reprinted in the Finding Aids section of the 
second volume containing chapter 1 (parts 52 to 99).

    The first volume, containing chapter 1 (parts 1 to 51), includes an 
index to the Federal acquisition regulations.

    For this volume, Karen A. Thornton was Chief Editor. The Code of 
Federal Regulations publication program is under the direction of 
Frances D. McDonald, assisted by Alomha S. Morris.

[[Page viii]]




[[Page 1]]



            TITLE 48--FEDERAL ACQUISITION REGULATIONS SYSTEM




                  (This book contains chapters 7 to 14)

  --------------------------------------------------------------------
                                                                    Part

Chapter 7--U.S. Agency for International Development........         701

Chapter 8--Department of Veterans Affairs...................         801

Chapter 9--Department of Energy.............................         901

Chapter 10--Department of the Treasury......................        1033

Chapter 12--Department of Transportation....................        1201

Chapter 13--Department of Commerce..........................        1301

Chapter 14--Department of the Interior......................        1401

[[Page 3]]



             CHAPTER 7--AGENCY FOR INTERNATIONAL DEVELOPMENT




  --------------------------------------------------------------------

  Editorial Note: Nomenclature changes to chapter 7 appear at 62 FR 
40466, July 29, 1997 and corrected at 62 FR 45334, August 27, 1997.

                          SUBCHAPTER A--GENERAL
Part                                                                Page
701             Federal Acquisition Regulation System.......           5
702             Definitions of words and terms..............          10
703             Improper business practices and personal 
                    conflicts of interest...................          13
704             Administrative matters......................          13
                   SUBCHAPTER B--ACQUISITION PLANNING
705             Publicizing contract actions................          15
706             Competition requirements....................          15
707             Acquisition planning........................          18
709             Contractor qualifications...................          18
711             Describing agency needs.....................          18
          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
713             Simplified acquisition procedures...........          20
714             Sealed bidding..............................          20
715             Contracting by negotiation..................          20
716             Types of contracts..........................          25
717             Special contracting methods.................          25
                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
719             Small business and small disadvantaged 
                    business concerns.......................          26
722             Application of labor laws to government 
                    acquisition.............................          30
724             Protection of privacy and freedom of 
                    information.............................          33
725             Foreign acquisition.........................          34
726             Other socioeconomic programs................          35
             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
728             Bonds and insurance.........................          39

[[Page 4]]

731             Contract cost principles and procedures.....          40
732             Contract financing..........................          44
733             Protests, disputes, and appeals.............          45
             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING
734             Major system acquisition....................          49
736             Construction and architect-engineer 
                    contracts...............................          49
737

[Reserved]

                    SUBCHAPTER G--CONTRACT MANAGEMENT
742             Contract administration.....................          51
749             Termination of contracts....................          51
750             Extraordinary contractual actions...........          52
                     SUBCHAPTER H--CLAUSES AND FORMS
752             Solicitation provisions and contract clauses          58
753             Forms.......................................          85

Appendix A to Chapter 7 
  [Reserved]*COM008*
Appendix B to Chapter 7 [Reserved]
Appendix C to Chapter 7 [Reserved]
Appendix D to Chapter 7--Direct USAID Contracts With a 
  U.S. Citizen or a U.S. Resident Alien for Personal 
  Services Abroad...........................................          86
Appendix E to Chapter 7 [Reserved]
Appendix F to Chapter 7--Use of Collaborative 
  Assistance Method for Title XII Activities................         111
Appendix G to Chapter 7 [Reserved]
Appendix H to Chapter 7 [Reserved]
Appendix I to Chapter 7--USAID's Academic Publication 
  Policy....................................................         115
Appendix J to Chapter 7--Direct USAID Contracts With a 
  Cooperating Country National and With a Third Country 
  National for Personal Services Abroad.....................         116

[[Page 5]]



                          SUBCHAPTER A--GENERAL





PART 701--FEDERAL ACQUISITION REGULATION SYSTEM--Table of Contents




               Subpart 701.1--Purpose, Authority, Issuance

Sec.
701.105  OMB approval under the Paperwork Reduction Act.

  Subpart 701.3--U.S. Agency for International Development Acquisition 
                               Regulation

701.370  Purpose.
701.371  Authority.
701.372  Applicability.
701.373  Code arrangement.
701.374  Publication.
701.375  Citation.
701.376  Agency implementation.
701.376-1  Responsibility.
701.376-2  AIDAR Notices.
701.376-3  Appendices.
701.376-4  Implementation within USAID contracting activities.
701.377  Procurement policy.

             Subpart 701.4--Deviations from the FAR or AIDAR

701.402  Policy.
701.470  Procedure.

         Subpart 701.6--Contracting Authority and Responsibility

701.601  General.
701.602-1  Authority of contracting officers in resolving audit 
          recommendations.
701.602-3  Ratification of unauthorized commitments.
701.603  Selection, appointment and termination of appointment.
701.603-70  Designation of contracting officers.

               Subpart 701.7--Determinations and Findings

701.704  Content.
701.707  Signatory authority.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13236, Apr. 3, 1984, unless otherwise noted.



               Subpart 701.1--Purpose, Authority, Issuance



701.105  OMB approval under the Paperwork Reduction Act.

    (a) The following information collection and record keeping 
requirements established by USAID have been approved by OMB, and 
assigned an OMB control number and approval/expiration dates as 
specified below:

                                                                        
------------------------------------------------------------------------
                                                                 Burden 
                                      OMB control   Expiration    hours 
            AIDAR segment                 No.          date        per  
                                                                 report 
------------------------------------------------------------------------
733.7003(c).........................    0412-0520      6/30/97        40
752.209-70..........................    0412-0520      6/30/97         4
752.219-8...........................    0412-0520      6/30/97         1
752.245-70..........................    0412-0520      6/30/97        .5
752.245-71..........................    0412-0520      6/30/97         1
752.7001(a).........................    0412-0520      6/30/97        .5
752.7001(b).........................    0412-0520      6/30/97        .5
752.7002(j).........................    0412-0520      6/30/97         1
752.7003............................    0412-0520      6/30/97         8
752.7004(b)(4)......................    0412-0520      6/30/97        .5
752.7032............................    0412-0520      6/30/97         2
752.7033............................    0412-0536      6/30/97         4
------------------------------------------------------------------------

    (b) The information requested by the AIDAR sections listed in 
paragraph (a) is necessary to allow USAID to prudently administer pubic 
funds. It lets USAID make reasonable assessments of contractor 
capabilities and responsibility of costs. Information is required in 
order for a contractor and/or its employee to obtain a benefit-usually 
taking the form of payment under a government contract.

[[Page 6]]

    (c) Public reporting burden for these collections of information is 
estimated as shown in paragraph (a) of this section. The estimated 
burden includes the time for reviewing instructions, searching existing 
data sources, gathering and maintaining the data needed, and completing 
and reviewing the collection of information. Send comments regarding the 
burden estimates or any other aspects of these collections of 
information, including suggestions for reducing the burden, to: US 
Agency for International Development, Office of Procurement, Policy 
Division (M/OP/P), Washington, DC 20523-1435; and Office of Management 
and Budget, OMB, Paper Reduction Project (0412-0520), Washington, DC 
20503.
[59 FR 33445, June 29, 1994, as amended at 61 FR 39090, July 26, 1996; 
62 FR 40466, July 29, 1997]



  Subpart 701.3--U.S. Agency for International Development Acquisition 
                               Regulation



701.370  Purpose.

    The U.S. Agency for International Development Acquisition Regulation 
(AIDAR) supplements the Federal Acquisition Regulation (FAR) and 
implements the procurement related aspects of the Foreign Assistance 
Act, Executive Order 11223. The AIDAR provides for the codification and 
publication of procedures for the acquisition of services and personal 
property by USAID.
[59 FR 33445, June 29, 1994, as amended at 61 FR 39090, July 26, 1996]



701.371  Authority.

    The AIDAR is prepared by the USAID Procurement Executive by 
direction of the Administrator of USAID pursuant to the Foreign 
Assistance Act of 1961. See FAR subpart 1.3.



701.372  Applicability.

    (a) Unless a deviation is specifically authorized in accordance with 
subpart 701.4, or unless otherwise provided, the FAR and AIDAR apply to 
all contracts (regardless of currency of payment, or whether funds are 
appropriated or non-appropriated) to which USAID is a direct party.
    (b) At Missions where joint administrative services are arranged, 
procuring offices may apply the Department of State Acquisition 
Regulation for all administrative and technical support contracts except 
in defined areas. The defined areas and administrative guidelines for 
procurement will be furnished to the overseas Missions by the Office of 
Administrative Services. Administrative and local support services 
include the procurement accountability, maintenance and disposal of all 
office and residential equipment and furnishings, vehicles and 
expendable supplies purchased with administrative and/or technical 
support funds, either dollars or local currency.
[49 FR 13236, Apr. 3, 1984, as amended at 49 FR 33667, Aug. 24, 1984; 55 
FR 6802, Feb. 27, 1990; 56 FR 67224, Dec. 30, 1991]



701.373  Code arrangement.

    (a) The Federal Acquisition Regulation System brings together, in 
title 48 of the Code of Federal Regulations, the procurement regulations 
that apply to all agencies of the Government. The FAR is chapter 1 of 
title 48; the AIDAR is chapter 7.
    (b) The FAR is divided into 53 parts; parts 1 through 53 of AIDAR 
expand upon or modify the policies and procedures included in the FAR. 
Material issued in the first 53 parts of the AIDAR will be numerically 
keyed to the corresponding sections of the FAR.
[49 FR 13230, Apr. 3, 1984, as amended at 62 FR 40466, July 29, 1997]



701.374  Publication.

    (a) Those parts of the AIDAR which contain basic and significant 
policies and procedures considered to be of interest to the general 
public will be published in the daily issues of the Federal Register 
and, in cumulated form, in the Code of Federal Regulations. Copies of 
the AIDAR in Federal Register and Code of Federal Regulations form may 
be purchased from the Superintendent of Documents, Government Printing 
Office, Washington, DC 20402.
    (b) Public participation will be obtained for significant revisions 
to the AIDAR by soliciting comments in accordance with FAR 1.501.

[[Page 7]]



701.375  Citation.

    Any section of the AIDAR may be identified by ``AIDAR'' followed by 
the section number. Within the AIDAR itself, internal references to an 
AIDAR section will cite the number only, and will not include the term 
``AIDAR''. Since the AIDAR is published in the Federal Register, any 
section may be incorporated into contracts by reference, using the 
citation ``48 CFR'' followed by the section number, as ``48 CFR 
703.375.''



701.376  Agency implementation.



701.376-1  Responsibility.

    Responsibility for the development and maintenance of the AIDAR is 
assigned to the Procurement Executive. Amendments and revisions will be 
prepared in coordination with the General Counsel, and such other 
offices as may be appropriate.
[49 FR 13236, Apr. 3, 1984, as amended at 50 FR 50301, Dec. 10, 1985]



701.376-2  AIDAR Notices.

    AIDAR Notices will be used to promulgate changes to the AIDAR. Such 
Notices will be prepared by the Procurement Executive.



701.376-3  Appendices.

    Significant procurement policies and procedures which do not 
correspond to or conveniently fit into the FAR system (described in FAR 
1.1 and this subpart) may be published as appendices to the AIDAR. 
Appendices follow the main text of the AIDAR in a section entitled 
``Appendices to Chapter 7'' and contain the individual appendices 
identified by letter and subject title (e.g., ``appendix D--Direct USAID 
Contracts with a U.S. Citizen or a U.S. Resident Alien for Personal 
Services Abroad'').
[62 FR 40466, July 29, 1997]



701.376-4  Implementation within USAID contracting activities.

    The heads of the various USAID contracting activities may issue 
operating instructions and procedures consistent with the FAR, AIDAR, 
and other Agency regulations, policies, and procedures for application 
within their organizations. One copy of each such issuance shall be 
forwarded to the Office of Procurement, Policy Division (M/OP/P). 
Insofar as possible, such material will be numerically keyed to the 
AIDAR.
[49 FR 13236, Apr. 3, 1984, as amended at 50 FR 50302, Dec. 10, 1985; 55 
FR 6802, Feb. 27, 1990; 56 FR 67224, Dec. 30, 1991; 59 FR 33445, June 
29, 1994]



701.377  Procurement policy.

    Subject to the direction of the Administrator, the Procurement 
Executive will be responsible for the development and maintenance of 
necessary uniform procurement policies, procedures, and standards; for 
providing assistance to the contracting activities as appropriate; for 
keeping the Administrator and Executive Staff fully informed on 
procurement matters which should be brought to their attention.



             Subpart 701.4--Deviations from the FAR or AIDAR



701.402  Policy.

    It is the policy of USAID that deviation from the mandatory 
requirements of the FAR and AIDAR shall be kept at a minimum and be 
granted only if it is essential to effect necessary procurement and when 
special and exceptional circumstances make such deviation clearly in the 
best interest of the Government.



701.470  Procedure.

    (a) Deviation from the FAR or AIDAR affecting one contract or 
transaction.
    (1) Deviations which affect only one contract or procurement will be 
made only after prior approval by the head of the contracting activity. 
Deviation requests containing the information listed in paragraph (c) of 
this section shall be submitted sufficiently in advance of the effective 
date of such deviation to allow adequate time for consideration and 
evaluation by the head of the contracting activity.
    (2) Requests for such deviations may be initiated by the responsible 
USAID contracting officer who shall obtain clearance and approvals as 
may be required by the head of the contracting

[[Page 8]]

activity. Prior to submission of the deviation request to the head of 
the contracting activity for approval, the contracting officer shall 
obtain written comments from the Office of Procurement, Policy Division 
(M/OP/P), hereinafter referred to as ``M/OP/P''. The M/OP/P shall 
normally be allowed 10 working days prior to the submission of the 
deviation request to the head of the contracting activity to review the 
request and to submit comments. If the exigency of the situation 
requires more immediate action, the requesting office may arrange with 
the M/OP/P for a shorter review period. In addition to a copy of the 
deviation request, the M/OP/P shall be furnished any background or 
historical data which will contribute to a more complete understanding 
of the deviation. The comments of the M/OP/P shall be made a part of the 
deviation request file which is forwarded to the head of the contracting 
activity.
    (3) Coordination with the Office of General Counsel, as appropriate, 
should also be effected prior to approval of a deviation by the head of 
the contracting activity.
    (b) Class deviations from the FAR or AIDAR: Class deviations are 
those which affect more than one contract or contractor.
    (1) Class deviations from the AIDAR will be processed in the same 
manner as prescribed in paragraph (a) of this section. Individual heads 
of contracting activities have authority to approve class deviations 
affecting only contracts within their own contracting activities, except 
that the Director, M/OP, has authority to approve class deviations that 
affect more than one contracting activity.
    (2) Class deviations from the FAR shall be considered jointly by 
USAID and the Chairperson of the Civilian Agency Acquisition Council (C/
CAAC) (FAR 1.404) unless, in the judgement of the head of the 
contracting activity, after due consideration of the objective of 
uniformity, circumstances preclude such consultation. The head of the 
contracting activity shall certify on the face of the deviation the 
reason for not coordinating with the C/CAAC. In such cases, the M/OP/P, 
shall be responsible for notifying the C/CAAC of the class deviation.
    (3) Class deviations from the FAR shall be processed as follows:
    (i) The request shall be processed in the same manner as paragraph 
(a) of this section, except that the M/OP/P, shall be allowed 15 working 
days prior to the submission of the deviation request to the head of the 
contracting activity to effect the necessary coordination with the C/
CAAC and to submit comments. If the exigency of the situation requires 
more immediate action, the requesting office may arrange with the M/OP/P 
for a shorter review and coordination period. The comments of the C/CAAC 
and the M/OP/P shall be made a part of the deviation request file which 
is forwarded to the head of the contracting activity.
    (ii) The request shall be processed in the same manner as paragraph 
(a) of this section if the request is not being jointly considered by 
USAID and the C/CAAC.
    (4) Deviations involving basic agreements or other master type 
contracts are considered to involve more than one contract.
    (5) Unless the approval is sooner rescinded, class deviations shall 
expire 2 years from the date of approval provided that deviation 
authority shall continue to apply to contracts or task orders which are 
active at the time the class deviation expires. Authority to continue 
the use of such deviation beyond 2 years may be requested in accordance 
with the procedures prescribed in paragraph (a) of this section.
    (6) Expiration dates shall be shown on all class deviations.
    (c) Requests for deviation shall contain a complete description of 
the deviation, the effective date of the deviation, the circumstances in 
which the deviation will be used, a specific reference to the regulation 
being deviated from, an indication as to whether any identical or 
similar deviations have been approved in the past, a complete 
justification of the deviation including any added or decreased cost to 
the Government, the name of the contractor, and the contract or task 
order number.
    (d) Register of deviations: Separate registers shall be maintained 
by the procuring activities of the deviations

[[Page 9]]

granted from the FAR and AIDAR. Each deviation shall be recorded in its 
appropriate register and shall be assigned a control number as follows: 
the symbol of the procuring activity, the abbreviation ``DEV'', the 
fiscal year, the serial number [issued in consecutive order during each 
fiscal year] assigned to the particular deviation and the suffix ``c'' 
if it is a class deviation, e.g. CM-DEV-85-1, CM-DEV-85-2c. The control 
number shall be embodied in the document authorizing the deviation and 
shall be cited in all references to the deviation.
    (e) Central record of deviations: Copies of approved deviations 
shall be furnished promptly to the M/OP/P, who shall be responsible for 
maintaining a central record of all deviations that are granted.
    (f) Semiannual report of class deviations:
    (1) USAID contracting officers shall submit a semiannual report to 
the M/OP/P of all contract actions effected under class deviations to 
the FAR and AIDAR which have been approved pursuant to paragraph (b) of 
this section.
    (2) The report shall contain the applicable deviation control 
number, the contractor's name, contract number and task order number (if 
appropriate).
    (3) The report shall cover the 6-month periods ending June 30 and 
December 31, respectively, and shall be submitted within 20 working days 
after the end of the reporting period.
[49 FR 13236, Apr. 3, 1984, as amended at 50 FR 50302, Dec. 10, 1985; 55 
FR 6802, Feb. 27, 1990; 56 FR 67224, Dec. 30, 1991; 59 FR 33445, June 
29, 1994; 61 FR 39090, July 26, 1996]



         Subpart 701.6--Contracting Authority and Responsibility



701.601  General.

    (a) Except as otherwise prescribed, the head of each contracting 
activity (as defined in 702.170) is responsible for the procurement of 
supplies and services under or assigned to the procurement cognizance of 
his or her activity. The heads of USAID contracting activities are 
vested with broad authority to carry out the programs and activities for 
which they are responsible. This authority includes authority to execute 
contracts and the establishment of procurement policies, procedures, and 
standards appropriate for their programs and activities, subject to 
Government-wide and USAID requirements and restrictions, such as those 
found at 701.376-4 and particularly 701.603-70, the USAID policy 
regarding the direct-hire status of contracting officers.
    (b) The authority of heads of contracting activities to execute 
contracts is limited as follows:
    (1) Director, Office of Procurement. Unlimited authority to execute 
contracts. May issue warrants for simplified acquisitions up to $50,000 
to individuals on his or her staff (subject to termination in accordance 
with FAR 1.603-4).
    (2) Director, Office of U.S. Foreign Disaster Assistance. Authority 
to execute contracts for disaster relief purposes during the first 72 
hours of a disaster in a cumulative total amount not to exceed $500,000. 
Authority to execute simplified acquisitions up to $50,000 at any time. 
May issue warrants for simplified acquisitions up to $50,000 to 
qualified individuals on his or her staff.
    (3) Director, Center for Human Capacity Development (G/HCD). 
Authority to execute simplified acquisitions up to $10,000. Unlimited 
authority for procuring participant training based on published catalog 
prices, using M/OP/E approved forms. May issue warrants for simplified 
acquisitions up to $10,000 to qualified individuals on his or her staff.
    (4) Overseas heads of contracting activities. Authority to sign 
contracts where the cumulative amount of the contract, as amended, does 
not exceed $250,000 (or local currency equivalent) for personal services 
contracts or $100,000 (or local currency equivalent) for all other 
contracts. May issue warrants for simplified acquisitions up to $50,000 
to qualified individuals on his or her staff.
[53 FR 4980, Feb. 19, 1988, as amended at 55 FR 6802, Feb. 27, 1990; 56 
FR 67224, Dec. 30, 1991; 58 FR 8702, Feb. 17, 1993; 59 FR 33445, June 
29, 1994; 60 FR 11912, Mar. 3, 1995; 61 FR 39090, July 26, 1996; 62 FR 
40466, July 29, 1997]

[[Page 10]]



701.602-1  Authority of contracting officers in resolving audit recommendations.

    With the exception of termination settlements subject to part 749, 
Termination of Contracts, contracting officers shall have the authority 
to negotiate and enter into settlerments with contractors for costs 
questioned under audit reports, or to issue a contracting officer's 
final decision pursuant to the disputes clauses (in the event that 
questioned costs are not settled by negotiated agreement) in accordance 
with ADS Chapter 591.5.20. The negotiated settlement or final decision 
shall be final, subject only to a contractor's appeal, either under the 
provisions of the Contract Disputes Act of 1978, as amended (41 U.S.C. 
601-613), or to the courts. Policies and procedures for resolving audit 
recommendations are in accordance with ADS Chapters 591 and 592.
[62 FR 40466, July 29, 1997]



701.602-3  Ratification of unauthorized commitments.

    (a) [Reserved]
    (b) Policy. (1) [Reserved]
    (2) In order to maintain management oversight and controls on 
unauthorized commitments, authority to ratify unauthorized commitments 
within USAID is reserved to the USAID Procurement Executive.
[53 FR 6829, Mar. 3, 1988]



701.603  Selection, appointment, and termination of appointment.



701.603-70  Designation of contracting officers.

    A contracting officer represents the U.S. Government through the 
exercise of his/her delegated authority to negotiate, sign, and 
administer contracts on behalf of the U.S. Government. The contracting 
officer's duties are sensitive, specialized, and responsible. In order 
to insure proper accountability, and to preclude possible security, 
conflict of interest, or jurisdiction problems, it is USAID policy that 
USAID contracting officers must be U.S. citizen direct-hire employees of 
the U.S. Government.
[49 FR 13236, Apr. 3, 1984, as amended at 61 FR 39091, July 26, 1996]



               Subpart 701.7--Determinations and Findings



701.704  Content.

    There is no USAID-prescribed format or form for determinations and 
findings (D&Fs). D&Fs are to contain the information specified in FAR 
1.704 and any information which may be required by the FAR or AIDAR 
section under which the D&F is issued.
[58 FR 8702, Feb. 17, 1993, as amended at 62 FR 40466, July 29, 1997]



701.707  Signatory authority.

    Unless otherwise specified in the FAR or AIDAR section under which 
the D&F is issued, the Contracting Officer is the signing official.
[58 FR 8702, Feb. 17, 1993]



PART 702--DEFINITIONS OF WORDS AND TERMS--Table of Contents




                      Subpart 702.170--Definitions

Sec.
702.170-1  USAID.
702.170-2  Administrator.
702.170-3  Contracting activities.
702.170-4  Cooperating country.
702.170-5  Cooperating country national (CCN).
702.170-6  Executive agency.
702.170-7  Foreign Assistance Act.
702.170-8  Government, Federal, State, local and political subdivisions.
702.170-9  Head of agency.
702.170-10  Head of the contracting activity.
702.170-11  Mission.
702.170-12  Overseas.
702.170-13  Procurement Executive.
702.170-14  Senior Procurement Executive.
702.170-15  Third country national (TCN).
702.170-16  U.S. national (USN).
702.170-17  Automated Directives System.

                   Subpart 702.270--Definitions Clause

702.270-1  Definitions clause.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

[[Page 11]]


    Source:  49 FR 13238, Apr. 3, 1984, unless otherwise noted.



                      Subpart 702.170--Definitions



702.170-1  USAID.

    USAID means the U.S. Agency for International Development and its 
predecessor agencies, including the International Cooperation 
Administration (ICA).



702.170-2  Administrator.

    Administrator means the Administrator or Deputy Administrator of the 
U.S. Agency for International Development.



702.170-3  Contracting activities.

    The contracting activities within USAID are:
    (a) The USAID/Washington activities. The contracting activities 
located in Washington are the Office of Procurement, Office of Foreign 
Disaster Assistance, and Center for Human Capacity Development (G/HCD). 
Subject to the limitations stated in 702.170-10, these contracting 
activities are responsible for procurement related to programs and 
activities for their areas. The Office of Procurement is responsible for 
procurements which do not fall within the responsibility of other 
contracting activities, or which are otherwise assigned to it.
    (b) The overseas field contracting activities. Each USAID Mission or 
post overseas is a contracting activity, responsible for procurement 
related to its programs and activities, subject to the limitations in 
702.170-10(b), which sets forth the contracting authority for Mission 
Directors and principal USAID officers at posts.
[50 FR 16085, Apr. 24, 1985, as amended at 50 FR 40528, Oct. 4, 1985; 50 
FR 50302, Dec. 10, 1985; 51 FR 20651, June 6, 1986; 56 FR 67224, Dec. 
30, 1991; 61 FR 39091, July 26, 1996; 62 FR 40466, July 29, 1997]



702.170-4  Cooperating country.

    Cooperating country means a foreign country in which there is a 
program or activity administered by USAID.



702.170-5  Cooperating country national (CCN).

    Cooperating country national (CCN) means an individual who is a 
cooperating country citizen or a non-cooperating country citizen 
lawfully admitted for permanent residence in the cooperating country.



702.170-6  Executive agency.

    Executive agency includes the U.S. Agency for International 
Development (USAID) and its predecessor agencies, including the 
International Cooperation Administration.



702.170-7  Foreign Assistance Act.

    Foreign Assistance Act means the Foreign Assistance Act of 1961, as 
amended (22 U.S.C., Chapter 32).



702.170-8  Government, Federal, State, local and political subdivisions.

    As used in the FAR and AIDAR, these terms do not refer to foreign 
entities except as otherwise stated.



702.170-9  Head of agency.

    Head of agency means, for USAID, the Administrator, and the Deputy 
Administrator, and in accordance with the responsibilities and 
limitations set forth in 702.170-13(c)(4), the Agency Procurement 
Executive.
[50 FR 52780, Dec. 26, 1985]



702.170-10  Head of the contracting activity.

    (a) The heads of USAID contracting activities are listed below. The 
limits of their contracting authority are set forth in 701.601.
    (1) USAID/Washington Heads of Contracting Activities:
    (i) Director, Office of Procurement;
    (ii) Director, Office of U.S. Foreign Disaster Assistance; and
    (iii) Director, Center for Human Capacity Development (G/HCD).
    (2) Overseas Heads of Contracting Activities: Each Mission Director 
or principal USAID officer at post (e.g. USAID Representative, USAID 
Affairs Officer, etc.)
    (b) Individuals serving in the positions listed in (a)(1) and (a)(2) 
of this section in an ``Acting'' capacity may

[[Page 12]]

exercise the authority delegated to that position.
[53 FR 4980, Feb. 19, 1988, as amended at 56 FR 67224, Dec. 30, 1991; 61 
FR 39091, July 26, 1996; 62 FR 40466, July 29, 1997]



702.170-11  Mission.

    Mission means the USAID mission or the principal USAID office or 
representative (including an embassy designated to so act) in a foreign 
country in which there is a program or activity administered by USAID.



702.170-12  Overseas.

    Overseas means outside the United States, its possessions, and 
Puerto Rico.



702.170-13  Procurement Executive.

    (a) Procurement Executive means the USAID official who:
    (1) Is responsible to the Administrator, through the Assistant 
Administrator for Management, for management direction of USAID's 
procurement system, including implementation of USAID's unique 
procurement policies, regulations, and standards, and
    (2) Oversees development of the system, evaluates system performance 
in accordance with approved criteria, and certifies to the 
Administrator, through the Assistant Administrator for Management, that 
the USAID procurement system meets approved criteria.
    (b) The Procurement Executive for USAID is Mr. Marcus L. Stevenson, 
the Director, Office of Procurement, Bureau for Management. Mr. 
Stevenson reports and makes recommendations to the Administrator, the 
Deputy Administrator, or other USAID officials, as appropriate, with 
regard to the implementation and improvement of the procurement system 
and procurement staffing to meet the objectives and requirements of the 
Foreign Assistance Act, Executive Order 12352, the Office of Federal 
Procurement Policy Act, and other statutory and Executive Branch 
procurement policies and requirements applicable to USAID operations. 
These reports and recommendations, including results of case reviews 
requested by the Director, Office of Procurement, will deal with the use 
of effective competition in procurement; establishment of clear lines of 
authority, accountability, and responsibility for procurement decision 
making within USAID; and development and maintenance of a procurement 
career management program to assure an adequate professional work force.
    (c) The USAID Procurement Executive has specific authority to:
    (1) Select and appoint contracting officers and terminate their 
appointments in accordance with section 1.603 of the Federal Acquisition 
Regulation;
    (2) Issue, develop, and maintain the Agency's acquisition 
regulations, procedures and standards for issuance in accordance with 
established agency delegations and requirements, as provided in subpart 
1.3 of the Federal Acquisition Regulation;
    (3) Exercise in person or by delegation the authorities stated in 
subpart 1.4 of the Federal Acquisition Regulation with regard to 
deviations from that regulation; and
    (4) Act for the Administrator, as ``head of the agency'' for all 
other purposes of the Federal Acquisition Regulation and the USAID 
Acquisition Regulation, except for the authority in FAR 6.302-7(a)(2), 
6.302-7(c)(1), 7.103, 17.602(a), 19.201(c)(2), 19.201(c)(3), 27.306(a), 
27.306(b), and 30.201-5 or where the ``head of the agency'' authority is 
expressly not redelegable under the FAR or AIDAR.
[50 FR 52781, Dec. 26, 1985, as amended at 52 FR 38097, Oct. 14, 1987; 
53 FR 50630, Dec. 16, 1988; 54 FR 37334, Sept. 8, 1989; 55 FR 6802, Feb. 
27, 1990; 56 FR 67224, Dec. 30, 1991; 59 FR 33445, June 29, 1994; 61 FR 
51234, Oct. 1, 1996]



702.170-14  Senior Procurement Executive.

    Senior Procurement Executive is synonymous with the term 
``Procurement Executive'', as defined in 702.170-13 of this subpart.
[50 FR 16086, Apr. 24, 1985]

[[Page 13]]



702.170-15  Third country national (TCN).

    Third country national (TCN) means an individual who is neither a 
cooperating country national nor a U.S. national, but is a citizen of a 
country included in Geographic Code 935 (see 22 CFR 228.3).
[49 FR 13238, Apr. 3, 1984. Redesignated at 50 FR 16086, Apr. 24, 1985, 
as amended at 62 FR 40466, July 29, 1997]



702.170-16  U.S. national (USN).

    U.S. national (USN) means an individual who is a U.S. citizen or a 
non-U.S. citizen lawfully admitted for permanent residence in the United 
States.
[49 FR 13238, Apr. 3, 1984. Redesignated at 50 FR 16086, Apr. 24, 1985]



702.170-17  Automated Directives System.

    Automated Directives System (``ADS'') means USAID's system of 
internal directives, regulations, and procedures. References to ``ADS'' 
throughout this chapter 7 are references to the Automated Directives 
System. Procurement-related sections of this system are accessible to 
the general public at internet address: http://www.info.usaid.gov/ftp--
data/pub/handbooks/index.html. The entire ADS in available on the 
Directives Resource Compact Disk (DR-CD), which may be purchased from 
the Agency at cost by submitting a completed DR-CD order form. To 
request a fax copy of the DR-CD order form, send an e-mail with your fax 
number to [email protected].
[62 FR 40466, July 29, 1997]



                   Subpart 702.270--Definitions Clause



702.270-1  Definitions clause.

    Use the appropriate clause in 752.202-1, in addition to the clause 
in FAR 52.202-1.



PART 703--IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST--Table of Contents




                        Subpart 703.1--Safeguards

Sec.
703.104-5  Disclosure, protection, and mark-    ing of proprietary and 
          source selection information.
703.104-11  Processing violations or possible violations.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



                        Subpart 703.1--Safeguards



703.104-5  Disclosure, protection, and marking of proprietary and source selection information.

    A Contracting Officer may authorize release of proprietary and/or 
source selection information outside the Government for evaluation 
purposes pursuant to (FAR) 48 CFR 15.413-2, Alternative II, as 
implemented by (AIDAR) 48 CFR 715.413-2, Alternate II.
[60 FR 11912, Mar. 3, 1995]



703.104-11  Processing violations or possible violations.

    The individual to whom the contracting officer should forward 
information and documentation as required in FAR 3.104-10 is the 
contracting officer's supervisor.
[62 FR 40467, July 29, 1997]



PART 704--ADMINISTRATIVE MATTERS--Table of Contents




   Subpart 704.4--Safeguarding Classified Information Within Industry

Sec.
704.404  Contract clause.

                Subpart 704.8--Contract Files [Reserved]

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



   Subpart 704.4--Safeguarding Classified Information Within Industry



704.404  Contract clause.

    If the contract involves access to classified (``Confidential'', 
``Secret'', or ``Top Secret''), or administratively

[[Page 14]]

controlled (``Sensitive But Unclassified'') information, use the 
contract clause in 752.204-2.
[49 FR 13239, Apr. 3, 1984. Redesignated at 54 FR 16122, Apr. 21, 1989, 
as amended at 62 FR 40467, July 29, 1997]



                Subpart 704.8--Contract Files [Reserved]

[[Page 15]]



                   SUBCHAPTER B--ACQUISITION PLANNING





PART 705--PUBLICIZING CONTRACT ACTIONS--Table of Contents




Sec.
705.002  Policy.

          Subpart 705.2--Synopsis of Proposed Contract Actions

705.202  Exceptions.
705.207  Preparation and transmittal of certain synopses.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445 (22 U.S.C. 2381), 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673, 3 CFR, 1979 Comp., 
p. 435; 40 U.S.C. 474.



705.002  Policy.

    (a) USAID's Office of Small and Disadvantaged Business Utilization 
maintains an USAID Consultant Registry Information System (ACRIS), which 
serves as a reference source and an indication of a prospective 
contractor's interest in performing USAID contracts. Prospective 
contractors are invited to file the appropriate form (Standard Forms 
254/255, Architect-Engineer and Related Services Questionnaire; or USAID 
Form 1420-50, USAID Consultant Registry Information System (ACRIS) 
Organization and Individual Profile) with USAID's Office of Small and 
Disadvantaged Business Utilization (Department of State, U.S. Agency for 
International Development, Washington, DC 20523-1414--Attention: Office 
of Small and Disadvantaged Business Utilization). These forms should be 
updated annually.
    (b) USAID policy is to include all Commerce Business Daily Notices 
and solicitations on the Internet.
[50 FR 40976, Oct. 8, 1985, and 50 FR 51396, Dec. 17, 1985, as amended 
at 52 FR 21058, June 4, 1987; 56 FR 2699, Jan. 24, 1991; 62 FR 40467, 
July 29, 1997]



          Subpart 705.2--Synopsis of Proposed Contract Actions



705.202  Exceptions.

    (a) [Reserved]
    (b) The head of the U.S. Agency for International Development has 
determined after consultation with the Administrator for Federal 
Procurement Policy and the Administrator of the Small Business 
Administration, that advance notice is not appropriate or reasonable for 
contract actions described in 706.302-70(b)(1) through (b)(3).
    (c) Advance notice is not required for contract actions undertaken 
in accordance with 706.302-71.
[51 FR 42845, Nov. 26, 1986, as amended at 54 FR 28069, July 5, 1989; 55 
FR 8469, Mar. 8, 1990; 55 FR 39154, Sept. 25, 1990; 56 FR 27208, June 
13, 1991; 57 FR 5235, Feb. 13, 1992]



705.207  Preparation and transmittal of certain synopses.

    The responsible contracting officer shall notify USAID's Office of 
Small and Disadvantaged Business Utilization (OSDBU) at least seven 
business days before publicizing a solicitation in the Commerce Business 
Daily for an acquisition:
    (a) Which is to be funded from amounts referred to in section 
706.302-71(a); and
    (b) Which is expected to exceed $100,000.

For exceptions, see 726.7005.
[56 FR 27208, June 13, 1991, as amended at 62 FR 40467, July 29, 1997]



PART 706--COMPETITION REQUIREMENTS--Table of Contents




Sec.
706.003  Definitions.

                    Subparts 706.1-706.2  [Reserved]

           Subpart 706.3--Other Than Full and Open Competition

706.302-5  Authorized or required by statute.
706.302-70  Impairment of foreign aid programs.
706.302-71  Small disadvantaged businesses.
706.303-1  Requirements.

                  Subpart 706.5--Competition Advocates

706.501  Requirement.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445 (22 U.S.C. 2381), 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673, 3 CFR, 1979 Comp., 
p. 435; 40 U.S.C. 474.

[[Page 16]]



706.003  Definitions.

    Procuring activity means ``contracting activity'', as defined in 
702.170-3.
[50 FR 40528, Oct. 4, 1985]



                    Subparts 706.1-706.2  [Reserved]



           Subpart 706.3--Other Than Full and Open Competition



706.302-5  Authorized or required by statute.

    Certain annual appropriations acts authorize USAID to contract with 
certain disadvantaged enterprises using other than full and open 
competition. The provisions implementing this authority are set forth in 
706.302-71 and part 726.
[58 FR 8702, Feb. 17, 1993, as amended at 62 FR 40467, July 29, 1997]



706.302-70  Impairment of foreign aid programs.

    (a) Authority. (1) Citation: 40 U.S.C. 474.
    (2) Full and open competition need not be obtained when it would 
impair or otherwise have an adverse effect on programs conducted for the 
purposes of foreign aid, relief, and rehabilitation.
    (b) Application. This authority may be used for:
    (1) An award under section 636(a)(3) of the Foreign Assistance Act 
of 1961, as amended, involving a personal services contractor serving 
abroad;
    (2) An award of $250,000 or less by an overseas contracting 
activity;
    (3)(i) An award for which the Assistant Administrator responsible 
for the project or program makes a formal written determination, with 
supporting findings, that compliance with full and open competition 
procedures would impair foreign assistance objectives, and would be 
inconsistent with the fulfillment of the foreign assistance program; or
    (ii) Awards for countries, regions, projects, or programs for which 
the Administrator of USAID makes a formal written determination, with 
supporting findings, that compliance with full and open competition 
procedures would impair foreign assistance objectives, and would be 
inconsistent with the fulfillment of the foreign assistance program.
    (4) Awards under AIDAR 715.613-70 (Title XII selection procedure--
general) or 715.613-71 (Title XII selection procedure--collaborative 
assistance).
    (5) An award for the continued provision of highly specialized 
services when award to another resource would result in substantial 
additional costs to the government or would result in unacceptable 
delays.
    (c) Limitations. (1) Offers shall be requested from as many 
potential offerors as is practicable under the circumstances. While the 
authority at 706.302-70(b)(5) is for use when the contracting officer 
determines that the incumbent contractor is the only practicable, 
potential offeror, the requirement to publicize the intended award, as 
required in FAR 5.201, still applies.
    (2) The contract file must include appropriate explanation and 
support justifying the award without full and open competition, as 
provided in FAR 6.303, except that determinations made under 706.302-
70(b)(3) will not be subject to the requirement for contracting officer 
certification or to approvals in accord with FAR 6.304.
    (3) The authority in 706.302-70(b)(3)(i) shall be used only when no 
other authority provided in FAR 6.302 or AIDAR 706.302 is suitable. The 
specific foreign assistance objective which would be impaired must be 
identified and explained in the written determination and finding. Prior 
consultation with the Agency Competition Advocate (see 706.501) is 
required before executing the written determination and finding, and 
this consultation must be reflected in the determination and finding.
    (4) Use of the authority in 706.302-70(b)(5) for proposed follow-on 
amendments in excess of one year or over $250,000 is subject to the 
approval of the Agency Competition Advocate. For all other follow-on 
amendments using this authority, the contracting officer's certification 
required in FAR 6.303-2(a)(12) will serve as approval.
[50 FR 40976, Oct. 8, 1985, and 50 FR 51395, Dec. 17, 1985, as amended 
at 54 FR 28069, July 5, 1989; 54 FR 46389, Nov. 3, 1989; 57 FR 5235, 
Feb. 13, 1992; 61 FR 39091, July 26, 1996; 62 FR 40467, July 29, 1997]

[[Page 17]]



706.302-71  Small disadvantaged businesses.

    (a) Authority. (1) Citations: Sec. 579, Pub. L. 101-167 (Fiscal Year 
(FY) 1990), Sec. 567, Pub. L. 101-513 (FY 1991), Sec. 567, Pbu. L. 102-
145 (FY 1992), Sec. 562, Pub. L. 102-391 (FY 1993), Sec. 558, Pub. L. 
103-87 (FY 1994), and Sec. 555, Pub. L. 103-306 (FY 1995).
    (2) Except to the extent otherwise determined by the Administrator, 
not less than ten percent of the amounts made available through the 
appropriations cited in paragraph (a)(1) of this section for development 
assistance and for assistance for famine recovery and development in 
Africa shall be used only for activities of disadvantaged enterprises 
(as defined in 726.7002). In order to achieve its goal, USAID is 
authorized in the cited statutes to use other than full and open 
competition to award contracts to small business concerns owned and 
controlled by socially and economically disadvantaged individuals (small 
disadvantaged businesses as defined in 726.7002), historically black 
colleges and universities, colleges and universities having a student 
body of which more than 40 percent of the students are Hispanic 
Americans, and private voluntary organizations which are controlled by 
individuals who are socially and economically disadvantaged, as the 
terms are defined in 726.7002.
    (b) Application. This authority may be used only if the Agency 
determines in accordance with 726.7004 that:
    (1) The acquisition is to be funded from amounts referred to in 
paragraph (a) of this section;
    (2) Award of the acquisition to an eligible organization is 
appropriate to meet the requirement in paragraph (a)(2) of this section; 
and
    (3) After considering whether the acquisition can be made under the 
authority of section 8(a), award under section 8(a) is not practicable.
    (c) Limitations. (1) Offers shall be requested from as many 
potential offerors as is practicable under the circumstances.
    (2) Use of this authority is not subject to the requirements in FAR 
6.303 and FAR 6.304, provided that the contract file includes a 
certification by the contracting officer stating that the procurement is 
being awarded pursuant to 706.302-71 and that the application 
requirements and limitations of 706.302-71 (b) and (c) have been 
complied with.
[56 FR 27208, June 13, 1991, as amended at 58 FR 8702, Feb. 17, 1993; 61 
FR 51235, Oct. 1, 1996; 62 FR 40467, July 29, 1997]



706.303-1  Requirements.

    (a)-(c)  [Reserved]
    (d) USAID project procurements are generally not subject to the 
Trade Agreements Acts of 1979 (see 725.403 of this chapter). To the 
extent procurements are made under the authority of FAR 6.302-3(a)(2)(i) 
or FAR 6.302-7 with Operating Expenses (OE) Funds, the Contracting 
Officer shall send a copy of the justification to the Office of the 
United States Trade Representative, 600 17th Street, NW., Washington, DC 
20506, ATTN: Director, International Procurement Policy.
[50 FR 16086, Apr. 24, 1985]



                  Subpart 706.5--Competition Advocates



706.501  Requirement.

    The USAID Administrator delegated the authority to designate the 
agency competition advocate and a competition advocate for each agency 
procuring activity (see 706.003 of this part) to the USAID Procurement 
Executive. The USAID Procurement Executive, under the Administrator's 
delegation, has designated the M/OP Deputy Director for Policy, 
Evaluation and Support as the Agency's competition advocate and the 
deputy head (or equivalent) of each contracting activity as the 
competition advocate for each activity. The competition advocate for M/
OP is the Deputy Director for Operations. If there is no deputy or 
equivalent, the head of the contracting activity is designated the 
competition advocate for that activity. The competition advocate's 
duties may not be redelegated, but can be exercised by persons serving 
as acting deputy (or acting head) of the contracting activity. For 
definitions of contracting activity and head of contracting activity, 
see 702.170-3 and 702.170-10, respectively.
[59 FR 33446, June 29, 1994]

[[Page 18]]



PART 707--ACQUISITION PLANNING--Table of Contents






               Subpart 707.1--Acquisition Plans [Reserved]



PART 709--CONTRACTOR QUALIFICATIONS--Table of Contents




Sec.

         Subpart 709.4--Debarment, Suspension and Ineligibility

709.403  Definitions.

           Subpart 709.5--Organizational Conflicts of Interest

709.503  Waiver.
709.507-2  Contract clause.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



         Subpart 709.4--Debarment, Suspension and Ineligibility



709.403  Definitions.

    Debarring official in USAID is the Procurement Executive.
    Suspending official in USAID is the Procurement Executive.
[62 FR 40467, July 29, 1997]



           Subpart 709.5--Organizational Conflicts of Interest



709.503  Waiver.

    For purposes of approving waivers or redelegating the authority to 
approve waivers pursuant to FAR 9.503, the USAID Procurement Executive 
is the Agency head (see (48 CFR) AIDAR 702.170-13(c)(4)). The 
Procurement Executive had redelegated the authority to approve waivers 
pursuant to FAR 9.503 to the heads of contracting acitivites in USAID, 
as defined in AIDAR 702.170-10.
[54 FR 16122, Apr. 21, 1989, as amended at 62 FR 40467, July 29, 1997]



709.507-2  Contract clause.

    (a)-(b) [Reserved]
    (c) In order to avoid problems from organizational conflicts of 
interest that may be discovered after award of a contract, the clause 
found at 752.209-71 should be inserted in all contracts whenever the 
solicitation includes one of the FAR organizational conflict of interest 
solicitation clauses, FAR 52.209-7 or 52.209-8.
[58 FR 42255, Aug. 9, 1993]



PART 711--DESCRIBING AGENCY NEEDS--Table of Contents




Sec.
711.002-70  Metric system waivers.
711.002-71  Solicitation provisions and contract clauses.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



711.002-70  Metric system waivers.

    (a) Criteria. The FAR 11.002(b) requirement to use the metric system 
of measurement for specifications and quantitative data that are 
incorporated in or required by USAID contracts may be waived when USAID 
determines in writing that such usage is impractical or is likely to 
cause U.S. firms to experience significant inefficiencies or the loss of 
markets.
    (b) Authorization. (1) The USAID Metric Executive (as designated in 
ADS chapter 323), the contracting officer, and the USAID official who 
approves the procurement requirement are authorized to waive the metric 
requirement for one of the above reasons. The USAID Metric Executive is 
authorized to overrule a decision to grant a waiver, or to nullify a 
blanket waiver made by another approving official so long as a 
contractor's rights under an executed contract are not infringed upon.
    (2) A blanket waiver for a class of multiple transactions may be 
issued for a term not to exceed three years.
    (3) When a waiver will be based upon the adverse impact on U.S. 
firms, clearance from the USAID Metric Executive and the Office of Small 
and Disadvantaged Business Utilization (SDB) will be obtained prior to 
authorization.
    (c) Records and reporting. (1) The basis for each waiver and any 
plans to adapt similar requirements to metric specifications in future 
procurements

[[Page 19]]

should be documented in the contract file.
    (2) Each procurement activity will maintain a log of the waivers 
from the metric requirements which are authorized for its procurements. 
The logs shall list the commodity/service being procured, total dollar 
value of the procured item(s), waiver date, authorizing official, basis 
for waiver, and USAID actions that can promote metrication and lessen 
the need for future waivers.
    (3) Within 30 days of the closing of each fiscal year, each USAID/W 
procurement activity and each Mission will submit a copy of the metric 
waiver log for the year to the USAID Metric Executive. (Mission logs are 
to be consolidated in a Mission report for the procurement activity and 
for the nonprocurement activities maintaining such logs under the USAID 
Metric Transition Plan.) Repetitive purchases of commercially produced 
and marketed items and classes of items may be consolidated in reporting 
procurements that do not exceed $10,000 cumulatively during the 
reporting period.
[57 FR 23321, June 3, 1992, as amended at 59 FR 33446, June 29, 1994. 
Redesignated and amended at 61 FR 39091, July 26, 1996. Redesignated and 
amended at 62 FR 40467, July 29, 1997]



711.002-71  Solicitation provisions and contract clauses.

    The contracting officer shall insert the clause at 752.211-70 in all 
USAID-direct solicitations and contracts.
[57 FR 23321, June 3, 1992. Redesignated and amended at 61 FR 39091, 
July 26, 1996]

[[Page 20]]



          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES





PART 713--SIMPLIFIED ACQUISITION PROCEDURES--Table of Contents




Sec.
713.000  Scope of part.

                         Subpart 713.1--General

713.101  Definitions.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR 1979 Comp., 
p. 435.

    Source:  61 FR 39091, July 26, 1996, unless otherwise noted.



713.000  Scope of part.

    The simplified acquisition threshold applies to the cost of supplies 
and services, exclusive of the cost of transportation and other 
accessorial costs if their destination is outside the United States.



                         Subpart 713.1--General



713.101  Definitions.

    Accessorial costs means the cost of getting supplies or services to 
their destination in the cooperating country (and the travel costs of 
returning personnel to the U.S. or other point of hire). It does not 
include costs such as allowances or differentials related to maintaining 
personnel at post which are to be considered as part of the base costs 
within the simplified acquisition threshold.



PART 714--SEALED BIDDING--Table of Contents




          Subpart 714.4--Opening of Bids and Award of Contract

Sec.
714.406-3  Other mistakes disclosed before award.
714.406-4  Disclosure of mistakes after award.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



          Subpart 714.4--Opening of Bids and Award of Contract



714.406-3  Other mistakes disclosed before award.

    The Procurement Executive is the designated central authority to 
make the determinations described in FAR 14.406-3.
[49 FR 13240, Apr. 3, 1984, as amended at 54 FR 46389, Nov. 3, 1989]



714.406-4  Disclosure of mistakes after award.

    The Procurement Executive is the designated central authority to 
make the determinations described in FAR 14.406-4.
[49 FR 13240, Apr. 3, 1984]



PART 715--CONTRACTING BY NEGOTIATION--Table of Contents




   Subpart 715.4--Solicitation and Receipt of Proposals and Quotations

Sec.
715.413-2  Alternate II.

                  Subpart 715.5--Unsolicited Proposals

715.502  Policy.
715.504  Advance guidance.
715.506  Agency procedures and point of contact.
715.506-1  Receipt, and initial review.

                     Subpart 715.6--Source Selection

715.604  Responsibilities.
715.604-70  Responsibilities of USAID evaluation committees.
715.605  [Reserved]
715.613-70  Title XII selection procedure--general.
715.613-71  Title XII selection procedure--collaborative assistance.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445 (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13240, Apr. 3, 1984, unless otherwise noted.

[[Page 21]]



   Subpart 715.4--Solicitation and Receipt of Proposals and Quotations



715.413-2  Alternate II.

    (a) A contracting officer may, subject to the requirements of this 
section and (FAR) 48 CFR 15.413-2, authorize release of proposals 
outside the Government for evaluation:
    (1) When an evaluation assistance contractor (EAC) is required to 
provide technical advisory or other services relating to the evaluation 
of proposals; or
    (2) When an individual other than a Government employee, known as a 
non-Government evaluator (NGE), is selected to serve as a member of an 
USAID technical evaluation committee.
    (b) Prior to releasing proposals outside the Government for 
evaluation, the contracting officer shall obtain a signed and dated copy 
of a certification and agreement from each NGE and EAC substantially as 
follows:

   Certification and Agreement for the Use and Disclosure of Proposals

    With respect to proposals submitted in response to USAID 
solicitation no. ________, the undersigned hereby agrees, and/or 
certifies, to the following:
    1. I will use the proposals, and all information therein other than 
information otherwise available without restriction, for evaluation 
purposes only. I will safeguard the proposals, and will not remove them 
from the site at which the evaluation is conducted unless authorized by 
the Contracting Officer. In addition, I will not disclose them, or any 
information contained in them (other than information otherwise 
available without restriction), except as directed or approved by the 
Contracting Officer.
    2. I will ensure that any authorized restrictive legends placed on 
the proposals by prospective contractors or subcontractors, or USAID, 
will be applied to any reproduction, or abstract of information, made by 
me.
    3. Upon completing the evaluation, I will return all copies of the 
proposals, and any abstracts thereof, to the USAID office which 
initially furnished them to me.
    4. Unless authorized by the contracting officer in advance in 
writing, I will not,--whether before, during, or after the evaluation--
contact any prospective contractor or subcontractor, or their employees, 
representatives or agents, concerning any aspect of the proposal.
    5. I have carefully reviewed my employment (past, present and under 
consideration) and financial interests, as well as those of my household 
family members. Based on this review, I certify, to the best of my 
knowledge and belief as of the date indicated below, that I either (1) 
have no actual or potential conflict of interest, personal or 
organizational, that could diminish my capacity to perform an impartial 
and objective evaluation of the proposals, or that might otherwise 
result in an unfair competitive advantage to one or more prospective 
contractors or subcontractors, or (2) have fully disclosed all such 
conflicts to the contracting officer, and will comply fully, subject to 
termination of my evaluation services, with any instructions by the 
contracting officer to mitigate, avoid, or neutralize conflicts(s). I 
understand that I will also be under a continuing obligation to 
disclose, and act as instructed concerning, such conflicts discovered at 
any time prior to the completion of the evaluation.

 Signature:_____________________________________________________________

 Name Typed or Printed:_________________________________________________

 Date:__________________________________________________________________

[60 FR 11912, Mar. 3, 1995, as amended at 62 FR 40467, July 29, 1997]



                  Subpart 715.5--Unsolicited Proposals



715.502  Policy.

    (a) USAID encourages the submission of unsolicited proposals which 
contribute new ideas consistent with and contributing to the 
accomplishment of the Agency's objectives. However, the requirements for 
contractor resources are normally quite program specific, and thus 
widely varied, and must be responsive to host country needs. Futher, 
USAID's projects are usually designed in collaboration with the 
cooperating country. These factors can limit both the need for, and 
USAID's ability to use unsolicited proposals. Therefore, prospective 
offerors are encouraged to contact USAID to determine the Agency's 
technical and geographical requirements as related to the offeror's 
interests before preparing and submitting a formal unsolicited proposal.
    (b) USAID's basic policies and procedures regarding unsolicited 
proposals are those established in FAR 15.5 and this subpart.
    (c) For detailed information on unsolicited proposals, see 715.504; 
for initial

[[Page 22]]

contact point within USAID, see 715.506.



715.504  Advance guidance.

    (a) Information concerning USAID's policies for unsolicited 
proposals is available from the U.S. Agency for International 
Development, Office of Procurement, Evaluation Division, Room 1600H, SA-
14, Washington, DC 20523-1435.
    (b) The information available concerns:
    (1) Contact points within USAID;
    (2) Definitions;
    (3) Characteristics of a suitable proposal;
    (4) Determination of contractor responsibility;
    (5) Organizational conflict of interest;
    (6) Cost sharing; and
    (7) Procedures for submission and evaluation of proposals.
[49 FR 13240, Apr. 3, 1984, as amended at 50 FR 50302, Dec. 10, 1985; 52 
FR 21058, June 4, 1987; 56 FR 2699, Jan. 24, 1991; 56 FR 67224, Dec. 30, 
1991; 59 FR 33446, June 29, 1994]



715.506  Agency procedures and point of contact.

    Initial inquiries and subsequent unsolicited proposals should be 
submitted to the address specified in section 715.504 of this subpart.
[56 FR 2699, Jan. 24, 1991]



715.506-1  Receipt, and initial review.

    USAID follows the policies and procedures established on FAR 15.506-
1 and 15.506-2.



                     Subpart 715.6--Source Selection



715.604  Responsibilities.



715.604-70  Responsibilities of USAID evaluation committees.

    (a) Establishment and composition of USAID evaluation committees. A 
technical evaluation committee shall be established for each proposed 
procurement. In each case, the committee shall be composed of a chair 
representing the cognizant technical office, a representative of the 
contracting office (who shall be a non-voting member of the committee), 
and representatives from other concerned offices as appropriate.
    (b) Technical evaluation procedures. (1) The contracting officer 
will receive all proposals and provide to the chair a listing and copies 
of the technical proposals and instructions for conducting the 
evaluation.
    (2) The chair will promptly call a meeting of the committee to 
evaluate the proposals received. The evaluation shall be based on the 
evaluation factors set forth in the solicitation document.
    (3) The chair shall prepare and provide to the contracting officer 
written documentation summarizing the results of the evaluation of each 
proposal, including an assessment of past performance information in 
accordance with FAR 15.608(a)(2) and section 752.209-70. The 
documentation shall include narrative justification of the evaluation 
results and shall reflect the requirements of FAR 15.608(a)(3).
    (4) The contracting officer is responsible for reviewing the 
documentation justifying the evaluation results to determine that it is 
adequate and complete. The contracting officer shall return a 
justification determined to be inadequate to the chair for revision.
    (5) No member of the USAID evaluation committee shall hold 
discussions with any offeror before or during the USAID evaluation 
committee's proceedings, nor shall any information about the proposals 
be provided to anyone not on the committee without first obtaining the 
contracting officer's consent.
[61 FR 39091, July 26, 1996]



715.605  [Reserved]



715.613  Alternative source selection procedures.



715.613-70  Title XII selection procedure--general.

    (a) General. The Deputy Administrator has determined, as provided in 
AIDAR 706.302-70(b)(3)(ii) that use of this Title XII source selection 
procedure is necessary so as not to impair or affect USAID's ability to 
administer Title XII of the Foreign Assistance Act. This determination 
is reflected in AIDAR 706.302-70(b)(4). This constitutes authority for 
other than full and open

[[Page 23]]

competition when selecting Title XII institutions to perform Title XII 
projects.
    (b) Scope of subsection. This subsection prescribes policies and 
procedures for the selection of institutions eligible under Title XII of 
the Foreign Assistance Act of 1961, as amended, to perform activities 
authorized under Title XII.
    (c) Applicability. The provisions of this subsection are applicable 
when the project office certifies that the activity is authorized under 
Title XII, and determines that use of the Title XII selection procedure 
is appropriate.
    (d) Solicitation, evaluation, and selection procedures. (1) 
Competition shall be sought among eligible Title XII institutions to the 
maximum practicable extent; this requirement shall be deemed satisfied 
when a contractor is selected under the procedures of this subsection.
    (2) The project office shall--
    (i) Prepare selection criteria for evaluation of eligible 
institutions for use in preparing the source list, determining 
predominantly qualified sources, and selecting the contractor;
    (ii) Prepare an initial list of eligible institutions considered 
qualified to perform the proposed activity;
    (iii) Provide a statement describing qualifications and areas of 
expertise considered essential, a statement of work, estimate of 
personnel requirements, special requirements (logistic support, 
government furnished property, and so forth) for the contracting 
officer's use in preparing the request for technical proposal (RFTP).
    (iv) Send a memorandum incorporating the certification and 
determination required by paragraph (c) of this section, together with 
the information required by paragraphs (d)(2) (i) through (iii) of this 
section, with the ``Action'' copy of the PIO/T to the contracting 
officer, requesting him/her to prepare and distribute the RFTP.
    (3) Upon receipt and acceptance of the project officer's request, 
the contracting officer shall prepare the RFTP. The RFTP shall contain 
sufficient information to enable an offeror to submit a responsive and 
complete technical proposal. This includes a definitive statement of 
work, an estimate of the personnel required, and special provisions 
(such as logistic support, government furnished equipment, and so 
forth), a proposed contract format, and evaluation criteria. No cost or 
pricing data will be requested or required by the RFTP. The RFTP will be 
distributed to the eligible institutions recommended by the project 
office. The RFTP will be synopsized, as required by FAR 5.201, and will 
normally allow a minimum of 60 days for preparation and submission of a 
proposal.
    (4) Upon receipt of responses to the RFTP by the contracting 
officer, an evaluation committee will be established as provided for in 
715.608 of this subpart.
    (5) The evaluation committee will evaluate all proposals in 
accordance with the criteria set forth in the RFTP, and will prepare a 
selection memorandum which shall:
    (i) State the evaluation criteria;
    (ii) List all of the eligible institutions whose proposals were 
reviewed;
    (iii) Report on the ranking and rationale therefor for all 
proposals;
    (iv) Indicate the eligible institution or institutions considered 
best qualified.
    (6) The evaluation committee will submit the selection memorandum to 
the contracting officer for review and approval.
    (7) The contracting officer will either approve the selection 
memorandum, or return it to the evaluation committee for reconsideration 
for specified reasons.
    (8) If the selection memorandum is approved, the contracting officer 
shall obtain cost, pricing, and other necessary data from the 
recommended institution or institutions and shall conduct negotiations. 
If a satisfactory contract cannot be obtained, the contracting officer 
will so advise the evaluation committee. The evaluation committee may 
then recommend an alternate institution or institutions.
[52 FR 6158, Mar. 2, 1987, as amended at 54 FR 28069, July 5, 1989; 55 
FR 6802, Feb. 27, 1990]



715.613-71  Title XII selection procedure--collaborative assistance.

    (a) General. (48 CFR) AIDAR 706.302-70(b)(4) provides authority for 
other than full and open competition when

[[Page 24]]

selecting Title XII institutions to perform Title XII activities.
    (b) Scope of subsection. This subsection prescribes policies and 
procedures for the selection of institutions eligible under Title XII of 
the Foreign Assistance Act of 1961, as amended, to perform activities 
authorized under Title XII, where USAID has determined, in accordance 
with paragraph (c) of this subsection, that use of the collaborative 
assistance contracting system is appropriate. See AIDR Appendix F (of 
this chapter)--Use of Collaborative Assistance Method for Title XII 
Activities for a more complete definition and discussion of the 
collaborative assistance method.
    (c) Determinations. The following findings and determinations must 
be made prior to initiating any contract actions under the collaborative 
assistance method:
    (1) The cognizant technical office makes a preliminary finding that 
an activity:
    (i) Is authorized by Title XII; and
    (ii) Should be classed as collaborative assistance because a 
continuing collaborative relationship between USAID, the host country, 
and the contractor is required from design through completion of the 
activity, and USAID, host country, and contractor participation in a 
continuing review and evaluation of the activity is essential for its 
proper execution.
    (2) Based upon this preliminary finding, the cognizant technical 
office shall establish an evaluation panel consisting of a 
representative of the cognizant technical office as chairman, a 
representative of the contracting officer, and any other representatives 
considered appropriate by the chairman to review the proposed activity 
for its appropriateness under the collaborative assistance method.
    (3) If supported by the panel's findings, the chairman will make a 
formal written determination that the collaborative assistance method is 
the appropriate contracting method for the Title XII activity in 
question.
    (d) Evaluation and selection. (1) Competition shall be sought among 
eligible Title XII institutions to the maximum practicable extent; this 
requirement shall be deemed satisfied when a contractor is selected 
under the procedures of this section.
    (2) The evaluation panel shall:
    (i) Prepare evaluation and selection criteria;
    (ii) Prepare an initial source list of eligible institutions 
considered qualified to perform the proposed project; and
    (iii) Evaluate the list, using the evaluation criteria previously 
determined, for the purpose of making a written determination of the 
sources considered most capable of performing the project.
    (3) The chairman of the evaluation panel will prepare a memorandum 
requesting the contracting officer to prepare a request for expressions 
of interest from qualified sources and setting forth:
    (i) The formal determinations required by paragraph (c) of this 
section;
    (ii) The evaluation criteria which have been determined; and
    (iii) The recommended source list and the rationale therefor.
    (4) The contracting officer will prepare a request for an expression 
of interest (REI), containing sufficient information to permit an 
offeror to determine its interest in the project, and to discuss the 
project with USAID representatives, if appropriate. The REI should 
include a concise statement of the purpose of the activity, any special 
conditions or qualifications considered important, a brief description 
of the selection procedure and evaluation criteria which will be used, 
the proposed contract format, and any other information considered 
appropriate. The REI will be issued to the sources recommended by the 
panel, and to others, as appropriate; it will be synopsized, as required 
by FAR 5.201, and it will normally allow a minimum of 60 days for 
preparation of an expression of interest. Guidelines for preparation of 
expressions of interest are contained in attachment 1 to AIDAR appendix 
F.
    (5) The contracting officer will transmit all expressions of 
interest to the evaluation panel for evaluation and selection 
recommendation. The panel may conduct on site evaluations at its 
discretion, as part of the evaluation process.
    (6) The chairman of the evaluation panel will prepare a written 
selection

[[Page 25]]

recommendation with supporting justification, recommending that 
negotiations be conducted with the prospective contractor(s) selected by 
the evaluation panel. The selection recommendation shall be transmitted 
to the contracting officer together with the complete official file on 
the project which was being maintained by the evaluation panel.
    (7) The contracting officer will review the selection 
recommendation, obtain necessary cost and other data, and proceed to 
negotiate with the recommended sources.
[52 FR 6159, Mar. 2, 1987, as amended at 54 FR 28069, July 5, 1989; 55 
FR 6802, Feb. 27, 1990; 62 FR 40467, July 29, 1997; 62 FR 45334, Aug. 
27, 1997; 62 FR 47532, Sept. 9, 1997]



PART 716--TYPES OF CONTRACTS--Table of Contents




               Subpart 716.3--Cost Reimbursement Contracts

Sec.
716.303  Cost-sharing contracts.
716.306  Cost-plus-fixed-fee contracts.

                        Subpart 716.5 [Reserved]

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445 (22 U.S.C. 2381) 
as amended: E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



               Subpart 716.3--Cost Reimbursement Contracts



716.303  Cost-sharing contracts.

    (a)-(b) [Reserved]
    (c) Limitations. In addition to the limitations specified in FAR 
16.301-3, prior approval of the USAID Procurement Executive (see 
702.170-13) is required in order to use a cost-sharing contract with an 
educational institution.
[54 FR 46390, Nov. 3, 1989]



716.306  Cost-plus-fixed-fee contracts.

    (a)-(b) [Reserved]
    (c) The Contracting Officer is authorized to sign the D&F specified 
in FAR 16.306(c)(2).
[58 FR 8702, Feb. 17, 1993]



                        Subpart 716.5 [Reserved]



PART 717--SPECIAL CONTRACTING METHODS--Table of Contents




    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



                 Subpart 717.70--Pharmaceutical Products



717.700  General.

    Section 606(c) of the Foreign Assistance Act bars procurement by the 
Government of drug and pharmaceutical products manufactured outside the 
United States if their manufacture involves the use of or is covered by 
an unexpired U.S. patent which has not been held invalid by an 
unappealed or unappealable court decision unless the manufacture is 
expressly authorized by the patent owner. Applicable policies and 
procedures are set forth in USAID Automated Directive System Chapter 
312.
[49 FR 13243, Apr. 3, 1984, as amended at 61 FR 39092, July 26, 1996]

[[Page 26]]



                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS





PART 719--SMALL BUSINESS AND SMALL DISADVANTAGED BUSINESS CONCERNS--Table of Contents




                         Subpart 719.2--Policies

Sec.
719.270  Small business policies.
719.271  Agency program direction and operation.
719.271-1  General.
719.271-2  The USAID Office of Small and Disadvantaged Business 
          Utilization (SDB).
719.271-3  USAID contracting officers.
719.271-4  Heads of contracting activities.
719.271-5  Cognizant technical officers.
719.271-6  Small business screening procedure.
719.271-7  Reports on procurement actions that are exempted from 
          screening.
719.272  Small disadvantaged business policies.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13243, Apr. 3, 1984, unless otherwise noted.



                         Subpart 719.2--Policies



719.270  Small business policies.

    (a) In keeping with section 602 of the Foreign Assistance Act of 
1961 (22 U.S.C. 2352), as amended, USAID shall, insofar as practicable 
and to the maximum extent consistent with the accomplishment of the 
purposes of said Act, assist United States small business to participate 
equitably in the furnishing of supplies and services for Foreign 
Assistance activities.
    (b) It is the policy of USAID to:
    (1) Fully endorse and carry out the Government's small business 
program for placing a fair proportion of its purchases and contracts for 
supplies, construction (including maintenance and repair), research and 
development, and services (including personal, professional, and 
technical services) with small business, including minority small 
business concerns; and
    (2) Increase their participation in USAID procurement.
    (c) In furtherance of this policy:
    (1) Cognizant technical officers shall make positive efforts (see 
719.271-5) to identify potentially qualified small and minority business 
firms during precontract development of activities and shall, with the 
responsible contracting officers, assure that such firms are given full 
opportunity to participate equitably;
    (2) Small business set-asides shall be made for all contracts to be 
executed in USAID/Washington which qualify for small business set-aside 
action under Part 19 of the FAR; and
    (3) Consideration shall be given in appropriate cases to the award 
of the contract to the Small Business Administration for subcontracting 
to small business firms pursuant to section 8(a) of the Small Business 
Act (15 U.S.C. 637(a)).
    (d) This program shall be implemented by all USAID/Washington 
contracting activities in order to attain these policy objectives. In 
accordance with 719.271, all USAID/Washington direct-procurement 
requirements which exceed the simplified acquisition threshold shall be 
screened for small business opportunities by the Office of Small and 
Disadvantaged Business Utilization (SDB) except those exempted by 
719.271-6(a).
    (e) Where practicable and desirable, small business and minority 
business enterprise award goals will be established for the respective 
USAID/Washington procuring activities to provide incentive for 
contracting personnel to increase awards to small firms. The goals will 
be set by SDB after consultation with the respective head of the 
contracting activity (see subsection 702.170-10).
    (f) In the event of a disagreement between SDB and the contracting 
officer concerning: (1) A recommended set-aside, or (2) a request for 
modification or withdrawal of a class or individual set-aside, complete 
documentation of the case including the reasons for disagreement shall 
be transmitted within five working days to the head of the contracting 
activity (see 719.271-6(e)) for a decision. Procurement action shall be 
suspended pending a decision.

[[Page 27]]

    (g) The above suspension shall not apply where the contracting 
officer:
    (1) Certifies in writing, with supporting information, that in order 
to protect the public interest award must be made without delay;
    (2) Promptly provides a copy of said certification to SDB; and
    (3) Includes a copy of the certification in the contract file.
    (h) SDB shall be the Small Business Advisor and Minority Business 
Procurement Policy Manager for all USAID/Washington procuring 
activities.
    (i) The details on the Agency's direction and operation of the small 
business program are set forth in 719.271.
    (j) No decision rendered, or action taken, under the coverage set 
forth in 719.271 shall preclude the Small Business Administration from 
appealing directly to the USAID Administrator as provided for in part 19 
of the FAR.
[49 FR 13243, Apr. 3, 1984, as amended at 52 FR 21058, June 4, 1987; 56 
FR 67224, Dec. 30, 1991; 61 FR 39092, July 26, 1996; 62 FR 40468, July 
29, 1997]



719.271  Agency program direction and operation.



719.271-1  General.

    The purpose of this section is to prescribe responsibilities and 
procedures for carrying out the small business program policy set forth 
in 219.270, and in part 19 of the FAR. Small Business concerns are 
defined in FAR subpart 19.1; in addition, small business concerns are 
concerns organized for profit. Nonprofit organizations are not 
considered small business concerns. Small disadvantaged business 
enterprises are defined in FAR subpart 19.1. Small disadvantaged 
business enterprises are included in the term ``small business'' when 
used in this subpart; specific reference to disadvantaged business 
enterprises is for added emphasis.



719.271-2  The USAID Office of Small and Disadvantaged Business Utilization (SDB).

    (a) SDB is responsible for administering, implementing, and 
coordinating the Agency's small business (including minority business 
enterprises) program.
    (b) SDB, headed by the Director SDB, who also serves as the Minority 
Business Procurement Manager, shall be specifically responsible for:
    (1) Developing policies, plans, and procedures for a coordinated 
Agency-wide small business and minority business enterprise procurement 
program;
    (2) Advising and consulting regularly with USAID/Washington 
procuring activities on all phases of their small business program, 
including, where practicable and desirable, the establishment of small 
business and minority business enterprise award goals;
    (3) Collaborating with officials of the Small Business 
Administration (SBA), other Government Agencies, and private 
organizations on matters affecting the Agency's small business program;
    (4) Developing and maintaining an USAID Consultant Registry 
Information System (ACRIS) of bidders/offerors (annotated to identify 
small business and minority business enterprise firms) capable of 
furnishing services for use by the USAID contracting activities;
    (5) Cooperating with contracting officers in administering the 
performance of contractors subject to the Small Business and Minority 
Business Enterprises Subcontracting Program clauses;
    (6) Developing a plan of operation designed to increase the share of 
contracts awarded to small business concerns, including small minority 
business enterprises;
    (7) Establishing small business class set-aside for types and 
classes of items of services where appropriate;
    (8) Reviewing each procurement requisition to make certain 
individual or class set-asides are initiated on all suitable USAID/
Washington proposed contract actions in excess of the simplified 
acquisition threshold which are subject to screening (see 719.271-6);
    (9) Maintaining a program designed to:
    (i) Locate capable small business sources for current and future 
procurements through GSA and other methods;
    (ii) Utilize every source available to determine if an item is 
obtainable from small business; and

[[Page 28]]

    (iii) Develop adequate small business competition on all appropriate 
procurements;
    (10) Taking action to assure that unnecessary qualifications, 
restrictive specifications, or other features (such as inadequate 
procurement lead time) of the programming or procurement process, which 
may prevent small business participation in the competitive process, are 
modified to permit such participation where an adequate product or 
service can be obtained;
    (11) Recommending that portions of large planned procurements or 
suitable components of end items or services be purchased separately so 
small firms may compete;
    (12) On proposed non-competitive procurements, recommending to the 
contracting officer that the procurement be made competitive when, in 
the opinion of SDB, there are small business or minority business 
enterprises believed competent to furnish the required goods or 
services, and supplying the contracting officer a list of such firms;
    (13) Assisting small business concerns with individual problems;
    (14) Promoting increased awareness by the technical staff of the 
availability of small business firms;
    (15) Making available to GSA copies of solicitations when so 
requested;
    (16) Counseling non-responsive or non-responsible small business 
bidders/offerors to help them participate more effectively in future 
solicitations; and
    (17) Examining bidders lists to make certain small business firms 
are appropriately identified and adequately represented for both 
negotiated and advertised procurements.
[49 FR 13243, Apr. 3, 1984, as amended at 52 FR 21058, June 4, 1987; 61 
FR 39092, July 26, 1996; 62 FR 40468, July 29, 1997]



719.271-3  USAID contracting officers.

    With respect to procurement activities within their jurisidiction, 
contracting officers are responsible for:
    (a) Being thoroughly familiar with part 19 of the FAR and this 
section dealing with the small business program;
    (b) Screening abstracts of bids and other award data to determine 
set-aside potential for future procurements;
    (c) Assuring that small business concerns and minority business 
enterprises are appropriately identified on source lists and abstracts 
of bids or proposals by an ``S'' and ``M'', respectively, or other 
appropriate symbol;
    (d) Reviewing types and classes of items and services to determine 
where small business set-asides can be applied;
    (e) Recommending that portions of large planned procurements of 
suitable components of end items or services be purchased separately so 
small firms may compete;
    (f) Making a unilateral determination for total or partial small 
business set-asides in accordance with Subpart 19.5 of the Federal 
Acquisition Regulations;
    (g) Submitting proposed procurement actions for USAID/Washington 
contracts to SDB for screening (see 719.271-6);
    (h) Taking action to assure that unnecessary qualifications, 
restrictive specifications or other features (such as inadequate 
procurement lead time) of the programming or procurement process which 
may prevent small business participation in the competitive process are 
modified to permit such participation where an adequate product or 
service can be obtained;
    (i) Prior to rendering a final decision on a proposed non-
competitive procurement action, and as part of his/her findings and 
determinations, the contracting officer shall consider the 
recommendations, if any, of SDB together with the latter's list of 
additional sources;
    (j) As appropriate, referring small business concerns, including 
small minority business enterprises, to SDB for information and advice;
    (k) Promoting increased awareness by the technical staff of the 
availability of small business concerns;
    (l) Making available to SDB copies of solicitations when requested;
    (m) Assisting SDB in counseling non-responsive or non-responsible 
small business bidders/offerors to help them to participate more 
effectively in future solicitations; and

[[Page 29]]

    (n) Including the Small Business and Minority Business Enterprises 
Subcontracting Program clauses in all contracts where required by part 
19 of the FAR.
[49 FR 13243, Apr. 3, 1984, as amended at 61 FR 39092, July 26, 1996; 62 
FR 40468, July 29, 1997]



719.271-4  Heads of contracting activities.

    In order for the agency small business program to be effective, the 
active support of top management is required. The heads of the 
contracting activities shall be responsible for:
    (a) Rendering decisions in cases resulting from non-acceptances by 
their contracting officers of set-aside recommendations made by SDB;
    (b) Consulting with SDB in establishing small business and minority 
business enterprise award goals, where practicable and desirable; and
    (c) Advising cognizant technical officers of their responsibilities 
as set forth in 719.271-5.
[49 FR 13243, Apr. 3, 1984, as amended at 61 FR 39092, July 26, 1996]



719.271-5  Cognizant technical officers.

    Since the procurement process starts with the establishment of a 
requirement, the actions of the cognizant technical officers can affect 
the opportunity of small business to participate equitably; therefore, 
each cognizant technical officer shall, during the formulation of 
activities which will require contractual implementation:
    (a) Consult with SDB on the availability and capabilities of small 
business firms to permit making a tentative set-aside determination 
where appropriate; and
    (b) Provide sufficient procurement lead time in the activity 
implementation schedule to allow potential small business participation.
[49 FR 13243, Apr. 3, 1984, as amended at 61 FR 39092, July 26, 1996]



719.271-6  Small business screening procedure.

    (a) General. All USAID/Washington proposed contract actions in 
excess of the simplified acquisition threshold shall be screened by SDB, 
with the exception of:
    (1) Class set-asides and those unilaterally set-aside by contracting 
officers (719.271-3(f));
    (2) Those where the contracting officer certifies in writing that 
the public exigency will not permit the delay incident to screening 
(719.271-7(b));
    (3) ``Institution building'' contracts (contracts for development of 
a counterpart capability in the host country) with educational or 
nonprofit institutions; or collaborative assistance contracts pursuant 
to AIDAR 715.613-71.
    (4) Those involving the payment of tuition and fees for participant 
training at academic institutions; and
    (5) Personal services contract requirements (see 719.270).
    (b) Preparation of Form USAID 1410-14 (the Small Business/Minority 
Business Enterprise Procurement Review Form). (1) The contracting 
officer shall prepare the subject form in an original and 3 copies and 
forward the original and 2 copies to SDB within one working day of 
receipt by the contracting activity of a procurement requisition.
    (2) The contracting officer will attach to his/her transmittal a 
complete copy of the procurement request and a copy of the recommended 
source list as furnished by the technical office and supplemented by 
him/her.
    (3) The contracting officer shall complete blocks 2, 3, 4, 5, 9, and 
10 (when appropriate) prior to submittal to SDB.
    (c) Screening of Form USAID 1410-14 by SDB. (1) SDB will screen the 
contracting officer's recommendations on set-aside potential, small 
business subcontracting opportunities, and section 8(a) subcontracting, 
and furnish him/her with either a written concurrence in his/her 
recommendations or written counter-recommendations on the original and 
duplicate copy within five working days from receipt of the form from 
the contracting officer.
    (2) SDB will complete Blocks 1, 6, 7, 8, 11, and 12 (when 
appropriate) prior to returning the screened form to the contracting 
officer.
    (d) Concurrence or rejection procedure. (1) The contracting officer 
shall complete Block 13 upon receipt of the original and duplicate copy 
of the screened form from SDB.

[[Page 30]]

    (2) If the contracting officer rejects the SDB counter-
recommendation, he/she shall return the original and duplicate forms 
with his/her written reasons for rejection to SDB within two working 
days.
    (3) Upon receipt of the contracting officer's rejection, SDB may: 
(i) accept, or (ii) appeal, the rejection. In the case of acceptance of 
the contracting officer's rejection, SDB shall annotate Block 14 when it 
renders a decision and return the original form to the contracting 
officer within two working days.
    (e) Appeal procedure. (1) When informal efforts fail to resolve the 
set-aside disagreement between the contracting officer and SDB, the 
latter official may appeal the contracting officer's decision to the 
head of the contracting activity. Such an appeal will be made within 
five working days after receipt of the contracting officer's rejection.
    (2) In the case of an appeal, SDB will send the original and 
duplicate form, with the appeal noted in Block 14, directly to the head 
of the contracting activity with its written reasons for appealing. The 
contracting officer will be notified of SDB's appeal by means of a copy 
of the written reasons for appealing.
    (3) The head of the contracting activity shall render a decision on 
the appeal (complete Block 15) within three working days after receipt 
of same and return the original to SDB and the duplicate to the 
contracting officer.
[49 FR 13243, Apr. 3, 1984, as amended at 52 FR 21058, June 4, 1987; 61 
FR 39092, July 26, 1996; 62 FR 40468, July 29, 1997]



719.271-7  Reports on procurement actions that are exempted from screening.

    (a) Unilateral and class set-asides. The contracting officer shall 
prepare Form USAID 1410-14 as stated in 719.271-6, but forward only the 
duplicate copy with the documentation required by Block 5 of the form to 
SDB. The original will be filed in the contract file.
    (1) If, upon review of the material submitted under 719.271-7(a) 
above, SDB concludes that it would be practicable to accomplish all or a 
portion of the procurement involved under section 8(a) subcontracting, 
it shall so advise the contracting officer in writing within five days 
after receipt of such material.
    (2) Such advice shall be considered a counter-recommendation and 
shall be processed in accordance with 719.271-6 (d) and (e).
    (b) Public exigency exemption. The contracting officer shall prepare 
Form USAID 1410-14 as stated in 719.271-6, but forward only the 
duplicate copy with the documentation required by Block 5 of the form to 
SDB. In addition to the documentation called for in 719.271-6, the 
contracting officer shall furnish a copy of his/her written 
determination exempting the procurement from screening. The 
determination shall cite the pertinent facts which led to his/her 
decision. This exemption is not intended to be used as substitute for 
good procurement planning and lead-time; SDB will report abuses of this 
exemption to the head of the contracting activity for appropriate action 
in accordance with 719.271-4(c).
    (c) Institution building contract (IBC) exemption. The contracting 
officer shall prepare Form USAID 1410-14 as stated in 719.271-6, but 
forward only the duplicate copy with the documentation required by Block 
5 of the form to SDB.
    (d) Personal services contract exemption. Preparation of Form USAID 
1410-14 is not required for personal services contracts.



719.272  Small disadvantaged business policies.

    In addition to the requirements in FAR part 19, part 726 provides 
for contracting and subcontracting with small disadvantaged businesses 
and other disadvantaged enterprises based on provisions of the foreign 
assistance appropriations acts.
[58 FR 8702, Feb. 17, 1993]



PART 722--APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITION--Table of Contents




                   Subpart 722.1--Basic Labor Policies

Sec.
722.103  Overtime.
722.103-1  Definitions.
722.103-2  Policy.
722.103-3  [Reserved]

[[Page 31]]

722.103-4  Approvals.
722.170  Employment of third country nationals (TCN's) and cooperating 
          country nationals (CCN's).

              Subpart 722.8--Equal Employment Opportuntity

722.805-70  Procedures.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13246, Apr. 3, 1984, unless otherwise noted.



                   Subpart 722.1--Basic Labor Policies



722.103  Overtime.



722.103-1  Definitions.

    Compensatory time off means leave equal to overtime worked, which, 
unless otherwise authorized in a contract or approved by a contracting 
officer, must be taken not later than the end of the calendar month 
following that in which the overtime is worked.



722.103-2  Policy.

    (a) Most contracts covered by this regulation call for the 
performance of professional or technical services overseas on a cost-
reimbursement basis. The compensation for employees performing such 
services is normally fixed on a monthly or annual basis, and the 
contracts usually state minimum work week hours. It is not expected that 
these employees will receive additional pay, overtime or shift premiums, 
or compensatory time off.
    (b) When the contracting officer determines it is in the best 
interests of the Government, specific provision may be made in contracts 
to permit such benefits for non-technical and non-professional employees 
serving overseas, subject to approvals to be required in the contract.
[49 FR 13246, Apr. 3, 1984. Redesignated at 61 FR 39092, July 26, 1996]



722.103-3  [Reserved]



722.103-4  Approvals.

    The contracting officer may make the determinations referred to in 
FAR 22.103-4.
[49 FR 13246, Apr. 3, 1984. Redesignated at 61 FR 39092, July 26, 1996]



722.170  Employment of third country nationals (TCN's) and cooperating country nationals (CCN's).

    (a) General. It is USAID policy that cooperating country nationals 
(CCN's) and third country nationals (TCN's), who are hired abroad for 
work in a cooperating country under USAID-direct contracts, generally be 
extended the same benefits, and be subject to the same restrictions as 
TCN's and CCN's employed as direct hires by the USAID Mission. 
Exceptions to this policy may be granted either by the Mission Director 
or the Assistant Administrator having program responsibility for the 
project. (TCN's and CCN's who are hired to work in the United States 
shall be extended benefits and subject to restrictions on the same basis 
as U.S. citizens who work in the United States.)
    (b) Compensation. Compensation, including merit or promotion 
increases paid to TCN's and CCN's may not, without the approval of the 
Mission Director or the Assistant Administrator having program 
responsibility for the project, exceed the prevailing compensation paid 
to personnel performing comparable work in the cooperating country as 
determined by the USAID Mission. Unless otherwise authorized by the 
Mission Director or the Assistant Administrator having program 
responsibility for the project, the compensation of such TCN and CCN 
employees shall be paid in the currency of the cooperating country.
    (c) Allowances and differentials. TCN's and CCN's, hired abroad for 
work in a cooperating country, are not eligible for allowances or 
differentials under

[[Page 32]]

USAID-direct contracts, unless authorized by the Mission Director or the 
Assistant Administrator having program responsibility for the project.
    (d) Country and security clearances. The contractor shall insure 
that the necessary clearances, including security clearances, if 
required, have been obtained for TCN and CCN employees in accordance 
with any such requirements set forth in the contract or required by the 
USAID Mission, prior to the TCN or CCN starting work under the contract.
    (e) Physical fitness. Contractors are required to insure that 
prospective TCN and CCN employees are examined prior to employment to 
determine whether the prospective employee meets the minimum physical 
requirements of the position and is free from any contagious disease.
    (f) Workweek, holidays, and leave. The workweek, holidays, and leave 
for TCN and CCN employees shall be the same as for all other employees 
of the contractor, under the terms of the contract; however, TCN and CCN 
employees are not eligible for home leave or military leave unless 
authorized by the Mission Director or the Assistant Administrator having 
program responsibility for the project.
    (g) Travel and transportation for TCN's and CCN's. Travel and 
transportation shall be provided TCN and CCN employees on the same basis 
as for all other employees of the contractor, under the terms of the 
contract.
    (h) Household effects and motor vehicles. USAID will not provide 
household effects to TCN and CCN employees; such employees may ship 
their household effects and motor vehicles to their place of employment 
on the same basis as for all other employees of the contractor, under 
the terms of the contract unless they are residents of the cooperating 
country.



               Subpart 722.8--Equal Employment Opportunity



722.805-70  Procedures.

    The following procedures apply, as appropriate, for all contracts:
    (a) General. (1) When all necessary representations and 
certifications (Reps and Certs) as required by FAR 22.810 are received, 
the contracting officer must review them to determine that they have 
been completed and signed as required, and are acceptable. Acceptable 
Reps and Certs are the first step in the EEO clearance process.
    (2) If the Reps and Certs are not deemed acceptable on technical 
grounds (e.g. incomplete, not signed, etc.) the contracting officer must 
decide if they can be made acceptable within a reasonable period by 
corrective action on the part of the offeror, or if the fault is such 
that it renders the offer nonresponsive. In the first case, necessary 
corrective action should be taken; in the second case, negotiations with 
the non-responsive offeror will be terminated. If the Reps and Certs 
raise questions concerning EEO compliance, and this would be the basis 
for finding the offeror non-responsive, the matter must be referred to 
the cognizant regional Department of Labor Office of Federal Contract 
Compliance Programs (OFCCP) regardless of the estimated value of the 
contract; only OFCCP may make a determination of non-compliance with EEO 
requirements.
    (b) Contracts for $1,000,000 or more. (1) In addition to the 
requirement for obtaining acceptable Reps and Certs in paragraph (a) of 
this section, contracts and modifications with an estimated value of 
$1,000,000 or more (including any modification which increases the total 
estimated value of a contract to $1,000,000 or more, or any modification 
which is itself $1,000,000 or more), must, in accordance with FAR 22.8, 
have OFCCP verification of EEO compliance before award. The contracting 
officer shall follow the procedures for obtaining EEO compliance in FAR 
22.805(a). In requesting a preaward review from OFCCP, the contracting 
officer may need to provide the following information in addition to the 
items listed in FAR 22.805(a)(4):
    (i) Name, title, address, and telephone number of a contact person 
for the prospective contractor;
    (ii) A description of the type of organization (university, 
nonprofit, etc.) and its ownership (private, foreign, state, etc.).
    (iii) Names and addresses of organizations in joint venture (if 
any).

[[Page 33]]

    (iv) Type of procurement (new contract--RFP or IFB, amendment, etc.) 
and estimated dollar amount, and term.
    (v) Copy of approved Reps and Certs.
    (2) If the initial contact with OFCCP is by telephone, the 
contracting officer and OFCCP should mutually determine what information 
is to be included in the written verification request. In the event that 
OFCCP reports that the offeror is not in compliance, negotiations with 
the offeror shall be terminated.
    (c) Contracts over $10,000, but less than $1,000,000. Contracts and 
amendments within this range do not require formal verification by 
OFCCP. The method used to verify compliance is at the discretion of the 
contracting officer. The contracting officer may rely on the 
documentation submitted by the offeror (the Reps and Certs--see 722.805-
70(a)), unless he or she is aware of some reason to doubt the 
documentation submitted. In case of doubt, then an informal check with 
OFCCP should be made. In the event that evidence of non-compliance is 
developed, the contracting officer must contact OFCCP for confirmation 
of EEO status; only OFCCP may determine non-compliance with EEO 
requirements. If OFCCP confirms non-compliance, negotiations with the 
offeror or contractor shall be terminated.
    (d) Documentation for the contract file. (1) Every contract file 
must contain completed signed Reps and Certs. The file must clearly show 
that these documents have been reviewed and accepted by the contracting 
officer. If the Reps and Certs were revised to make them acceptable (see 
722.805-70(a)), the file must show what changes were required and 
certify that the changes were made.
    (2) For contracts or amendments of $1,000,000 or more, the file must 
contain:
    (i) A record of the initial contact with OFCCP, specifying the name, 
address, and telephone number of the person contacted, a summary of the 
information presented, and the advice given by OFCCP;
    (ii) A copy of the written follow-up request for EEO compliance 
verification to OFCCP; and
    (iii) A copy of the compliance verification from OFCCP.
    (3) For contracts or amendments over $10,000 but less than 
$1,000,000, the file must contain a statement from the contracting 
officer that the contractor is considered in compliance with EEO 
requirements, and giving the basis for this statement (see 722.805-
70(c)). This statement may be in a separate memorandum to the file or in 
the memorandum of negotiation.
    (4) Documentation in the event of non-compliance. In the event that 
OFCCP determines that a prospective contractor is not in compliance, a 
copy of OFCCP's written determination, and a summary of resultant action 
taken (termination of negotiations, notification of offeror and 
cognizant technical officer, negotiation with next offeror in 
competitive range, resolicitation, etc.) will be placed in the contract 
file for any contract which may result, together with other records 
related to unsuccessful offers, and retained for at least six months 
following award.
[61 FR 39092, July 26, 1996; 61 FR 42939, Aug. 19, 1996, as amended at 
62 FR 40468, July 29, 1997]]



PART 724--PROTECTION OF PRIVACY AND FREEDOM OF INFORMATION--Table of Contents




                Subpart 724.2--Freedom of Information Act

Sec.
724.202  Policy.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13248, Apr. 3, 1984, unless otherwise noted.



                Subpart 724.2--Freedom of Information Act



724.202  Policy.

    The U.S. Agency for International Development's policies concerning 
implementation of the Freedom of Information Act are codified in 22 CFR 
part 212 (USAID Regulation 12).

[[Page 34]]



PART 725--FOREIGN ACQUISITION--Table of Contents




                Subpart 725.1--Buy American Act--Supplies

Sec.
725.170  Exceptions for Foreign Assistance Act functions.

                     Subpart 725.4--Trade Agreements

725.403  Exceptions.

             Subpart 725.70--Source, Origin, and Nationality

725.701  General.
725.702  Designation of authorized geographic code.
725.703  Contractor employees.
725.704  Source, origin and nationality requirements--Contract clause.
725.705  Local procurement--contract clause.
725.706  Geographic source waivers.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13248, Apr. 3, 1984, unless otherwise noted.



                Subpart 725.1--Buy American Act--Supplies



725.170  Exceptions for Foreign Assistance Act functions.

    In addition to the exception stated in FAR 25.102 for purchases for 
use outside the United States, there is an exception for economic 
assistance functions performed under authority of the Foreign Assistance 
Act. This exception is stated in Executive Order 11223, dated May 12, 
1965 (30 FR 6635). U.S. procurement restrictions are applied by USAID, 
however, as shown elsewhere in this part. These restrictions are 
generally tighter than the Buy American Act. As a general rule, the 
tighter USAID restrictions will be used. In the case of certain 
procurements for use within the United States, the Buy American 
provision may be used instead in the interest of uniformity among 
Federal Agencies procuring for domestic use.



                     Subpart 725.4--Trade Agreements



725.403  Exceptions.

    FAR 25.4 establishes procedures for purchases under the Trade 
Agreements Act of 1979 (including GATT's Agreement on Government 
Procurement) and the North American Free Trade Agreement (NAFTA). Under 
both such agreements, USAID's contracts for the purpose of providing 
foreign assistance are not subject to the procedures set forth in FAR 
25.4. In contrast, USAID's operating expense-type administrative 
purchases (i.e., purchases for the direct benefit and use of USAID) are 
subject to the procedures in FAR 25.4, unless otherwise exempted by one 
of the exemptions specified in FAR 25.4.
[61 FR 39093, July 26, 1996]



             Subpart 725.70--Source, Origin, and Nationality



725.701  General.

    USAID's source, origin and nationality requirements for program-
funded contracts and subcontracts are established in 22 CFR part 228, 
Rules on Source, Origin and nationality for Commodities and Services 
Financed by USAID. These policies as they apply to subcontracts and 
purchases under USAID program-funded contracts have been incorporated 
into the contract clauses referenced in 725.704 and 725.705 of this 
subpart.
[62 FR 40468, July 29, 1997]



725.702  Designation of authorized geographic code.

    (a) The authorized geographic code or codes for an USAID contract 
shall be specified in the Schedule of each contract and shown on its 
cover page. If no geographic code is specified, the authorized code will 
be deemed to be Geographic Code 000, the U.S.
    (b) Individual country and geographic codes are defined in the 
Agency Geographic Code Book.
[49 FR 13248, Apr. 3, 1984, as amended at 61 FR 39093, July 26, 1996]

[[Page 35]]



725.703  Contractor employees.

    (a) Except as specifically provided in paragraph (b) of this 
section, there are no nationality restrictions on employees or 
consultants of either contractors or subcontractors providing services 
under an USAID-financed contract, except that they must be citizens of a 
Geographic Code 935 country, or non-U.S. citizens lawfully admitted for 
permanent residence in the U.S.
    (b) For USAID-financed construction projects where the contract is 
awarded to a U.S. firm, at least half of the supervisors, and any other 
specified key personnel, working at the project site must be U.S. 
citizens or permanent legal residents of the United States. Exceptions 
may be authorized by the Mission Director in writing if special 
circumstances make compliance impractical.
[51 FR 34985, Oct. 1, 1986]



725.704  Source, origin and nationality requirements--Contract clause.

    The clause in 752.225-70 is required in all USAID program-funded 
contracts under which the contractor may procure goods or services.
[62 FR 40468, July 29, 1997]



725.705  Local procurement--contract clause.

    Local procurement may be undertaken in accordance with the 
provisions of 22 CFR 228.40. All contracts involving performance 
overseas shall contain the clause in 752.225-71.
[62 FR 40468, July 29, 1997]



725.706  Geographic source waivers.

    (a) Authority to waive source, origin, nationality, and 
transportation services requirements is set forth in chapters 103 and 
310 of the ADS.
    (b) The contracting officer shall insert the authorized geographic 
code based on an approved geographic source waiver in the Schedule of 
the contract as provided for in 725.702. In addition, the contracting 
officer shall place a copy of any approved geographic source waiver in 
the official contract file.
[49 FR 13248, Apr. 3, 1984, as amended at 52 FR 4144, Feb. 10, 1987; 61 
FR 39093, July 26, 1996; 62 FR 40468, July 29, 1997]



PART 726--OTHER SOCIOECONOMIC PROGRAMS--Table of Contents




            Subpart 726.70--Disadvantaged Enterprises Program

Sec.
726.7001  Scope of subpart.
726.7002  Definitions.
726.7003  Policy.
726.7004  Determination to use other than full and open competition.
726.7005  Exceptions.
726.7006  Determination of status as a disadvantaged enterprise.
726.7007  Requirement for subcontracting with disadvantaged enterprises.
726.7008  Limitations on subcontracting.

  Subpart 726.71--Relocation of U.S. Businesses, Assistance to Export 
      Processing Zones, Internationally Recognized Workers' Rights

726.7101  Policy.
726.7102  PD 20 provision.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O.12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  55 FR 8470, Mar. 8, 1990, unless otherwise noted.



            Subpart 726.70--Disadvantaged Enterprises Program



726.7001  Scope of subpart.

    This subpart supplements FAR part 19 and implements the provisions 
of certain foreign assistance appropriations acts (see section 706.302-
71(a)) concerning disadvantaged enterprises which require, in general, 
that not less than ten percent of the aggregate amount made available 
for development assistance and for assistance for famine recovery and 
development in Africa shall be made available to disadvantaged 
enterprises. See part 705 and part 706 for additional provisions on 
publicizing contract actions and

[[Page 36]]

using other than full and open competition.
[58 FR 8702, Feb. 17, 1993. Redesignated and amended at 61 FR 39093, 
July 26, 1996; 62 FR 40468, July 29, 1997]



726.7002  Definitions.

    (a) Controlled by socially and economically disadvantaged 
individuals means management and daily business are controlled by one or 
more such individuals.
    (b) Disadvantaged enterprises means U.S. organizations or 
individuals that are:
    (1) Business concerns (as defined in FAR 19.001) owned and 
controlled by socially and economically disadvantaged individuals;
    (2) Institutions designated by the Secretary of Education, pursuant 
to 34 CFR 608.2, as historically black colleges and universities;
    (3) Colleges or universities having a student body in which more 
than 40 percent of the students are Hispanic American; or
    (4) Private voluntary organizations which are controlled by 
individuals who are socially and economically disadvantaged.
    (c) Economically disadvantaged individuals has the same meaning as 
in FAR 19.001, except that the term includes women.
    (d) Owned by socially and economically disadvantaged individuals 
means at least 51 percent owned by one or more individuals who are both 
socially and economically disadvantaged, or a publicly owned business 
having at least 51 percent of its stock owned by one or more socially 
and economically disadvantaged individuals.
    (e) Small disadvantaged business means a small business concern (as 
defined in FAR 19.001) that is at least 51 percent unconditionally owned 
by one or more individuals who are both socially and economically 
disadvantaged (as defined in this section), or a publicly owned business 
that has at least 51 percent of its stock unconditionally owned by one 
or more socially and economically disadvantaged individuals (as defined 
in this section) and that has its management and daily business 
controlled by one or more such individuals.
    (f) Socially disadvantaged individuals has the same meaning as in 
FAR 19.001, except that the term includes women.
[56 FR 27209, June 13, 1991, as amended at 56 FR 52212, Oct. 18, 1991. 
Redesignated at 61 FR 39093, July 26, 1996]



726.7003  Policy.

    USAID promotes participation in its projects by disadvantaged 
enterprises. In order to achieve the goals in foreign assistance 
appropriation acts, contracts which are to be funded from amounts made 
available from the appropriations cited in section 706.302-71(a)(1) are 
subject to the following policies:
    (a) Authority in section 8(a) of the Small Business Act (15 U.S.C. 
637(a)) shall be used to the maximum practicable extent;
    (b) Other than full and open competition in contracting with certain 
disadvantaged enterprises shall be authorized in accordance with 
706.302-71;
    (c) Subcontracting with disadvantaged enterprises shall be carried 
out in accordance with section 726.7007;
    (d) In accordance with 705.207, the Office of Small and 
Disadvantaged Business Utilization (OSDBU) shall be notified at least 
seven business days before publicizing a proposed procurement in excess 
of $100,000.
[56 FR 27209, June 13, 1991. Redesignated at 61 FR 39093, July 26, 1996, 
as amended at 62 FR 40468, July 29, 1997]



726.7004  Determination to use other than full and open competition.

    The determinations required in order to use the authority under 
706.302-71 for other than full and open competition shall be made by the 
contracting officer in consultation with the Director of OSDBU. In the 
event of a disagreement between the contracting officer and the Director 
of OSDBU, the head of the contracting activity shall make the final 
determination.
[55 FR 8470, Mar. 8, 1990. Redesignated at 61 FR 39093, July 26, 1996.]



726.7005  Exceptions.

    The notification requirement in 705.207 and the subcontracting 
requirement in 726.7007 are based on statutory requirement and may not 
be deviated

[[Page 37]]

from under the provisions of subpart 701.4. By statute, the 
Administrator or designee may determine that these requirements do not 
apply to a particular contract or category of contracts. The Procurement 
Executive has been designated to make such determinations. One such 
determination concerning subcontracting is set out in 726.7007.
[58 FR 8702, Feb. 17, 1993. Redesignated at 61 FR 39093, July 26, 1996, 
as amended at 62 FR 40468, July 29, 1997]



726.7006  Determination of status as a disadvantaged enterprise.

    (a) To be eligible for an award under AIDAR 706.302-71 providing for 
other than full and open competition, the contractor must qualify, as of 
both the date of submission of its offer and the date of contract award, 
as a small disadvantaged business (as defined in 726.7002), an 
historically black college or university, a college or university in 
which more than 40 percent of the students are Hispanic Americans, or a 
private voluntary organization controlled by individuals who are 
socially and economically disadvantaged. The contracting officer shall 
insert the provision at 752.226-1 in any solicitation or contract to be 
awarded under the provisions of 706.302-71.
    (b) The contracting officer shall accept an offeror's 
representations and certifications under the provisions referenced above 
that it is a small disadvantaged business unless he or she determines 
otherwise based on information contained in a challenge of the offeror's 
status by the Small Business Administration or another offeror, or 
otherwise available to the contracting officer.
[55 FR 8470, Mar. 8, 1990, as amended at 56 FR 27209, June 13, 1991. 
Redesignated at 61 FR 39093, July 26, 1996, as amended at 62 FR 40468, 
July 29, 1997]



726.7007  Requirement for subcontracting with disadvantaged enterprises.

    (a) In addition to the requirements in FAR subpart 19.7, any new 
contract or modification which constitutes new procurement (except for a 
contract or modification with a disadvantaged enterprise as defined in 
726.7002) with respect to which more than $500,000 is to be funded with 
amounts made available for development assistance or from the 
appropriations cited in section 706.302-71(a)(1) shall contain a 
provision requiring that not less than ten percent of the dollar value 
of the contract must be subcontracted to disadvantaged enterprises, 
including disadvantaged enterprises which are not small.
    (b) This requirement does not apply when the contracting officer, 
with the concurrence of the Director of OSDBU, certifies there is no 
realistic expectation of U.S. subcontracting opportunities and so 
documents the file. If the contracting officer and the Director of OSDBU 
do not agree, the determination will be made by the head of the 
contracting activity. See 726.7005 for guidance on other potential 
exceptions.
    (c) The contracting officer shall insert the clause in 752.226-2 in 
any solicitation or contract as provided in paragraph (a) of this 
section, unless exempted in accordance with the provisions of paragraph 
(b) of this section.
[55 FR 8470, Mar. 8, 1990, as amended at 56 FR 27209, June 13, 1991; 56 
FR 52213, Oct. 18, 1991; 58 FR 42255, Aug. 9, 1993. Redesignated at 61 
FR 39093, July 26, 1996, as amended at 62 FR 40468, July 29, 1997; 62 FR 
47532, Sept. 9, 1997]



726.7008  Limitations on subcontracting.

    The contracting officer shall insert the clause at 752.226-3, 
Limitations on Subcontracting, in any solicitation and contract for 
technical assistance services which is to be awarded under the authority 
of 706.302-71.
[58 FR 42255, Aug. 9, 1993. Redesignated at 61 FR 51235, Oct. 1, 1996]



  Subpart 726.71--Relocation of U.S. Businesses, Assistance to Export 
      Processing Zones, Internationally Recognized Workers' Rights



726.7101  Policy.

    USAID Policy Determination (PD) 20, ``Guidelines to Assure USAID 
Programs do not Result in the Loss of Jobs in the U.S.'' implemented 
statutory prohibitions on expenditure of appropriated funds. The PD 
contains a standard provision for inclusion in USAID-funded grants and 
inter-agency agreements and indicates that when

[[Page 38]]

the PD applies to a contract, appropriate provisions covering the 
subject matter are to be included. When the provisions of PD 20 do apply 
to a contract, the cognizant technical office shall provide to the 
contracting officer appropriate language tailored to the specific 
circumstances for the contract statement of work, or if applicable to 
the circumstances, the provision included in the PD (see 726.7102) may 
be used as a clause in the contract. The provision is not required in 
subcontracts.
[61 FR 39093, July 26, 1996]



726.7102  PD 20 provision.

 Relocation of U.S. Businesses, Assistance to Export Processing Zones, 
          Internationally Recognized Workers' Rights (Jan 1994)

    No funds or other support provided hereunder may be used in an 
activity reasonably likely to involve the relocation or expansion 
outside of the United States of an enterprise located in the United 
States if non-U.S. production in such relocation or expansion replaces 
some or all of the production of, and reduces the number of employees 
at, said enterprise in the United States.
    No funds or other support provided hereunder may be used in an 
activity the purpose of which is the establishment or development in a 
foreign country of any export processing zone or designated area where 
the labor, environmental, tax, tariff, and safety laws of the country 
would not apply, without the prior approval of USAID.
    No funds or other support provided hereunder may be used in an 
activity which contributes to the violation of internationally 
recognized rights of workers in the recipient country, including those 
in any designated zone or area in that country.
[61 FR 39093, July 26, 1996]

[[Page 39]]



             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS





PART 728--BONDS AND INSURANCE--Table of Contents




                          Subpart 728.1--Bonds

Sec.
728.105-1  Advance payment bonds.

                        Subpart 728.3--Insurance

728.305-70  Overseas worker's compensation and war-hazard insurance--
          waivers and USAID insurance coverage.
728.307-2  Liability.
728.307-70  Medical Evacuation (MEDEVAC) Services (Mar 1993).
728.309  Contract clause for worker's compensation insurance.
728.313  Contract clauses for insurance of transportation or 
          transportation-related services.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13249, Apr. 3, 1984, unless otherwise noted.



                          Subpart 728.1--Bonds



728.105-1  Advance payment bonds.

    (a) Generally, advance payment bonds will not be required in 
connection with USAID contracts containing an advance payment provision. 
In lieu thereof, contracting officers will follow procedures set forth 
in FAR 32.409-3.
    (b) Whenever a contracting officer considers that an advance payment 
bond is necessary, the contracting officer will: (1) Establish a bond 
penalty that will adequately protect interests of the Government, (2) 
use the USAID Advance Payment Bond format, (3) place bond with a surety 
currently approved by the U.S. Treasury Department according to the 
latest Treasury Department Circular 570, (4) stipulate that the cost of 
the bond shall not exceed a rate of $7.50 per $1,000 per annum based on 
the penalty of the bond, without the prior written approval of the 
Office of Procurement, Policy Division (M/OP/P).
    (c) Where the surety's obligation under an advance payment bond 
covers all advances made to the contractor during the term of the 
contract, no release should be issued to the surety until all advances 
made and to be made under the contract have been fully liquidated in 
accordance with the provisions of the contract, such as no-pay vouchers, 
reports of expenditures, or by refund. Where the surety's obligation 
under the bond is limited to advances made during a specified period of 
time, no release should be issued to the surety until all advances made 
and to be made during the specified period have been liquidated as 
aforesaid.
[49 FR 13249, Apr. 3, 1984, as amended at 50 FR 50302, Dec. 10, 1985; 55 
FR 6802, Feb. 27, 1990; 56 FR 67224, Dec. 30, 1991; 59 FR 33446, June 
29, 1994]



                        Subpart 728.3--Insurance



728.305-70  Overseas worker's compensation and war-hazard insurance--waivers and USAID insurance coverage.

    (a) Upon the recommendation of the USAID Administrator, the 
Secretary of Labor may waive the applicability of the Defense Base Act 
(DBA) with respect to any contract, subcontract, or subordinate 
contract, work location, or classification of employees. Either the 
contractor or USAID can request a waiver from coverage. Such a waiver 
can apply to any employees who are not U.S. citizens, not residents of, 
or not hired in the United States. Waivers requested by the contractor 
are submitted to the contracting officer for approval and further 
submission to the Department of Labor, which grants the waiver. 
Application for a waiver is submitted on Labor Department Form BEC 565. 
USAID has a number of blanket waivers already in effect for certain 
countries that are applicable to its direct contracts with contractors 
performing in such countries. Where such waivers are granted from 
coverage under the DBA, the waiver is conditioned on providing other 
worker's compensation coverage to employees to which the waiver applies. 
Usually this takes the form of securing worker's compensation coverage 
of the country where work will be performed

[[Page 40]]

or of the country of the employee's nationality, whichever offers 
greater benefits. The Department of Labor has granted partial blanket 
waivers of DBA coverage applicable to USAID-financed contracts performed 
in certain countries, subject to two conditions:
    (1) Employees hired in the United States by the contractor, and 
citizens or residents of the United States are to be provided DBA 
insurance coverage;
    (2) Waived employees (i.e., employees who are neither U.S. citizens 
nor U.S. resident aliens, and who were hired outside the United States) 
will be provided worker's compensation benefits as required by the laws 
of the country in which they are working or the laws of their native 
country, whichever offers greater benefits. Information as to whether a 
DBA Waiver has been obtained by USAID for a particular country may be 
obtained from the cognizant USAID contracting officer.
    (b) To assist contractors in securing insurance at minimal rates for 
the workmen's compensation insurance required under the DBA, and to 
facilitate meeting insurance requirements for such coverage, USAID, 
after open and competitive negotiation, has entered into a contract with 
an insurance carrier to provide such coverage at a specified rate. The 
terms of this contract require the insurance carrier to provide 
coverage, and the contractor to make payments to and handle its claims 
with that insurance carrier. Contracting officers are responsible for 
explaining and advising contractors of the details of securing such 
insurance.
[49 FR 13249, Apr. 3, 1984, as amended at 52 FR 4144, Feb. 10, 1987. 
Redesignated at 53 FR 50630, Dec. 16, 1988, and amended at 54 FR 16122, 
Apr. 21, 1989; 56 FR 67224, Dec. 30, 1991]



728.307-2  Liability.

    (a)-(b) [Reserved]
    (c) Automobile liability. In order to ensure that private 
automobiles used by contractor employees stationed overseas under an 
USAID contract are properly insured, USAID has established minimum 
required coverages as a supplement to the FAR clause at 52.228-7. This 
supplemental coverage is specified in AIDAR 752.228-7, and is to be used 
in all USAID-direct contracts involving performance overseas.
[53 FR 50630, Dec. 16, 1988]



728.307-70  Medical Evacuation (MEDEVAC) Services (Mar 1993).

    The Contracting Officer shall insert the clause at 752.228-70 in all 
contracts which require performance by contractor employees overseas.
[59 FR 33446, June 29, 1994]



728.309  Contract clause for worker's compensation insurance.

    (a) Because of the volume of projects performed overseas resulting 
in contracts which require worker's compensation insurance, USAID has 
contracted with an insurance carrier to provide the required insurance 
for all USAID contractors. It is therefore necessary to supplement the 
FAR clause at 52.228-3 with the additional coverage specified in AIDAR 
752.228-3. The coverage specified in AIDAR 752.228-3 shall be used in 
addition to the coverage specified in FAR 52.228-3 in all USAID-direct 
contracts involving performance overseas.
[53 FR 50630, Dec. 16, 1988]



728.313  Contract clauses for insurance of transportation or transportation-related services.

    (a) USAID is required by law to include language in all its direct 
contracts and subcontracts ensuring that all U.S. marine insurance 
companies have a fair opportunity to bid for marine insurance when such 
insurance is necessary or appropriate under the contract. USAID has 
therefore established a supplementary preface to the clause at FAR 
52.228-9. This supplementary preface is set forth in AIDAR 752.228-9, 
and is required for use in any USAID-direct contract where marine 
insurance is necessary or appropriate.
[53 FR 50630, Dec. 16, 1988]



PART 731--CONTRACT COST PRINCIPLES AND PROCEDURES--Table of Contents




                      Subpart 731.1--Applicability

Sec.
731.109  Advance agreements.

[[Page 41]]

         Subpart 731.2--Contracts With Commercial Organizations

731.205-6  Compensation for personal services.
731.205-46  Travel costs.
731.205-70  Overseas recruitment incentive.

         Subpart 731.3--Contracts With Educational Institutions

731.370  Predetermined fixed rates for indirect costs.
731.371  Compensation for personal services.
731.372  Fringe benefits.
731.373  Overseas recruitment incentive.

          Subpart 731.7--Contracts With Nonprofit Organizations

731.770  OMB Circular A-122; cost principles for nonprofit 
          organizations; USAID implementation.
731.771  Bid and proposal costs.
731.772  Compensation for personal services.
731.773  Independent research and development costs.
731.774  Overseas recruitment incentive.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13250, Apr. 3, 1984, unless otherwise noted.



                      Subpart 731.1--Applicability



731.109  Advance agreements.

    Advance agreements on selected costs may be negotiated with USAID 
contractors by the Overhead and Special Cost and Contract Close-Out 
Branch, Office of Procurement. Such advance understandings will be 
applicable to all USAID contracts with that contractor.
[49 FR 13250, Apr. 3, 1984, as amended at 50 FR 50302, Dec. 10, 1985; 51 
FR 20651, June 6, 1986]



         Subpart 731.2--Contracts With Commercial Organizations



731.205-6  Compensation for personal services.

    (a) General. When establishing the workweek for employees overseas 
the contractor will take local and USAID Mission practice into account 
and will insure that the workweek is compatible with that of those USAID 
Mission and Cooperating Country employees with whom the contractor will 
be working.
    (b)-(c) [Reserved]
    (d) Salaries and wages. It is USAID policy that if an employee's 
base salary plus overseas recruitment incentive, if any (see AIDAR 
731.205-70), exceeds the maximum hourly, daily, or annual rate for a 
Executive Service level ES-6, it will be allowable only if approved in 
writing by the Contracting Officer. (The Contracting Officer shall only 
provide such approval after internal Agency procedures for review/
approval of salaries in excess of the ES-6 rate have been followed.) 
USAID policies on compensation of third country national or cooperating 
country national employees are set forth in AIDAR 722.170.
    (e)-(l) [Reserved]
    (m) Fringe benefits. USAID's policies on certain fringe benefits 
related to overseas service, including but not limited to leave, 
holidays, differentials and allowances, etc. are set forth in the 
appropriate contract clauses in AIDAR subpart 752.70.
[57 FR 5235, Feb. 13, 1992, as amended at 60 FR 11913, Mar. 3, 1995; 62 
FR 40468, July 29, 1997]



731.205-46  Travel costs.

    It is USAID policy to require prior written approval of 
international travel by the Contacting Officer. See AIDAR 752.7032 for 
specific requirements and procedures.
[57 FR 5236, Feb. 13, 1992]



731.205-70  Overseas recruitment incentive.

(Note: the term employee as used in this section means an employee who 
is a U.S. citizen or a U.S. resident alien.)

    (a) If a contractor employee serving overseas under a contract does 
not qualify for the exemption for overseas income provided under section 
911 of the U.S. Internal Revenue Code (26 U.S.C. 911), such employee is 
eligible to receive an overseas recruitment incentive (ORI), to the 
extent the ORI: Is authorized by the contractor's normal policy and 
practice; is deemed necessary by the contractor to recruit and retain 
qualified employees for overseas services; and does not exceed 10% of 
the base salary of the employee from

[[Page 42]]

date of arrival at overseas post to begin assignment to date of 
departure from post at the end of assignment. ORI is to be paid as a 
single payment at the end of the employee tour of duty overseas. The 
contractor shall take all reasonable and prudent steps to ensure that 
ORI is not paid to any employee who has received the IRS section 911 
exemption.
    (b) In the event that an employee subsequently receives a section 
911 exclusion for any part of the base salary upon which this supplement 
has been paid, such supplement or appropriate portion thereof shall be 
reimbursed by the contractor to USAID with interest. The interest shall 
be calculated at the average U.S. Treasury rate in effect for the period 
that the contractor or his employee had the funds. Neither the 
contractor's nor the subcontractor's inability to collect refunds from 
eligible employees shall be used as a basis to excuse subsequent refunds 
by the contractor to USAID.
[57 FR 5236, Feb. 13, 1992]



         Subpart 731.3--Contracts With Educational Institutions



731.370  Predetermined fixed rates for indirect costs.

    Section 635(k) of the Foreign Assistance Act of 1961, as amended, 
authorizes USAID to use predetermined fixed rates in determining the 
indirect costs applicable under contracts with educational institutions.



731.371  Compensation for personal services.

    (a) General. When establishing the workweek for employees overseas 
the contractor will take local and USAID Mission practice into account 
and will ensure that the workweek is compatible with that of those USAID 
Mission and Cooperating Country employees with whom the contractor will 
be working.
    (b) Salaries and wages. (1) It is USAID policy that if an employee's 
base salary plus overseas recruitment incentive, if any (see AIDAR 
731.205-70), exceeds the maximum hourly, daily, or annual rate for a 
Executive Service level ES-6, it will be allowable only if approved in 
writing by the Contracting Officer. The Contracting Officer shall only 
provide such approval after internal Agency procedures for review/
approval of salaries in excess of the ES-6 rate have been followed.
    (2) In considering consulting income as a factor when determining 
allowable salary for service under a contract:
    (i) For faculty members working under annual appointments, salary 
for service under the contract may include the employee's on-campus 
salary plus ``consulting income'' (that is, income from employment other 
than the employee's regular on-campus appointment, excluding business or 
other activities not connected with the employee's profession) earned 
during the year preceding employment under the contract.
    (ii) For faculty members working under academic year appointments, 
salary for service under the contract may include the employee's on-
campus academic year salary plus ``consulting income'' as defined above 
earned during the year proceeding employment under the contract, or 
salary for service under the contract may be derived by annualizing the 
academic year salary (in which case ``consulting income'' may not be 
included).
    (3) USAID policies and compensation of third country national or 
cooperating country national employees are set forth in AIDAR 722.170.
[57 FR 5236, Feb. 13, 1992, as amended at 60 FR 11913, Mar. 3, 1995; 62 
FR 40469, July 29, 1997]



731.372  Fringe benefits.

    USAID's policies on certain fringe benefits related to overseas 
service, including but not limited to leave, holidays, differentials and 
allowances, etc. are set forth in the appropriate contract clauses in 
AIDAR 752.70.
[57 FR 5236, Feb. 13, 1992]



731.373  Overseas recruitment incentive.

    USAID's policies regarding overseas recruitment incentives are set 
forth in AIDAR 731.205-70. These policies are also applicable to 
contracts with an educational institution.
[57 FR 5236, Feb. 13, 1992]

[[Page 43]]



          Subpart 731.7--Contracts With Nonprofit Organizations



731.770  OMB Circular A-122, cost principles for nonprofit organizations; USAID implementation.

    (a) Paragraph 6 of the transmittal letter for OMB Circular A-122 
specifies that ``Agencies shall designate a liaison official to serve as 
the agency representative on matters relating to the implementation of 
this Circular.'' The Director, Office of Procurement, has been so 
designated. The Overhead and Special Cost and Contract Close-Out Branch, 
Office of Procurement (OCC) provides staff assistance to the Director 
concerning OMB Circular A-122. OCC is also responsible for obtaining 
cognizance under the criteria in the transmittal letter for OMB Circular 
A-122; for liaison with other cognizant agencies; for authorizing 
exclusion of OMB Circular A-122 coverage for a particular nonprofit 
organization pursuant to paragraph 5 of the OMB Circular A-122 
transmittal letter; and for advice and assistance in applying OMB 
Circular A-122 cost principles.
    (b) Paragraph 4b of the OMB Circular A-122 transmittal letter 
contains a definition of prior approval as follows:

    Prior approval means securing the awarding agency's permission in 
advance to incur costs for those items that are designated as requiring 
prior approval by OMB Circular A-122. Generally, this permission will be 
in writing. Where an item of cost requiring prior approval is specified 
in the budget of an award, approval of the budget constitute approval of 
that cost.


Consequently, an award containing a budget constitutes prior approval of 
the direct cost item in the budget, unless otherwise annotated. 
Accordingly, award budgets should be appropriately annotated 
substantially as follows:

    Inclusion of any cost in the line item budget of this award does not 
obviate the requirement for prior approval of cost items designated as 
requiring prior approval by OMB Circular A-122 ; or
    In accordance with the requirements to OMB Circular No. A-122, 
approval is granted to incur costs for (name specific item or items) 
which are included in the budget of this award.
[49 FR 13250, Apr. 3, 1984, as amended at 50 FR 50302, Dec. 10, 1985; 51 
FR 20651, June 6, 1986; 56 FR 67225, Dec. 30, 1991]



731.771  Bid and proposal costs.

    Pending the establishment of Government-wide principles in 
Attachment B of OMB Circular A-122, USAID will treat bid and proposal 
costs as follows:
    (a) Bid and proposal costs are the costs of preparing bids, 
proposals, and applications for potential activities such as Government 
and non-Government grants, contracts and other agreements, including the 
development of scientific, cost, and other data needed to support such 
bids, proposals, and applications. Except as provided in (b) below, bid 
and proposal costs of the current accounting period of both successful 
and unsuccessful bids and proposals normally should be treated as 
indirect costs for allocation to all current activities, and no bid and 
proposal costs of past accounting periods will be allocable to the 
current period. However, if the organization's established practice is 
to treat bid and proposal costs by some other method, the results 
obtained may be accepted only if found to be reasonable and equitable.
    (b) Bid and proposal costs incurred by the organization to obtain 
unrestricted funds are to be treated as fund raising and allocated an 
appropriate share of indirect costs under the conditions described in 
paragraph B.3 of Attachment A to OMB Circular A-122.



731.772  Compensation for personal services.

    The policies set for in AIDAR 731.205-6 are also applicable to 
contracts with a nonprofit organization.
[57 FR 5236, Feb. 13, 1992]



731.773  Independent research and development costs.

    Pending establishment of Government-wide principles in Attachment B 
of OMB Circular A-122, USAID will apply the cost principles at FAR 
31.205-18 for independent research and development costs.

[[Page 44]]



731.774  Overseas recruitment incentive.

    USAID's policies regarding overseas recruitment incentives are set 
forth in AIDAR 731.205-70. These policies are also applicable to 
contracts with a nonprofit organization.
[57 FR 5236, Feb. 13, 1992]



PART 732--CONTRACT FINANCING--Table of Contents




                    Subpart 732.1--Contract Financing

Sec.
732.111  Contract clauses.

                     Subpart 732.4--Advance Payments

732.401  Statutory authority.
732.402  General.
732.403  Applicability.
732.406-70  Agency-issued letters of credit.
732.406-71  Circumstances for use of an LOC.
732.406-72  Establishing an LOC.
732.406-73  LOC contract clause.
732.406-74  Revocation of the LOC.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



                         Subpart 732.1--General



732.111  Contract clauses.

    (a) [Reserved]
    (b) USAID may obtain short term and (less frequently) long-term 
indefinite quantity professional services through Agency-specific 
indefinite quantity contracts that are a combination of contract types. 
Rather than using the fixed-price payment clauses for indefinite 
quantity contracts, when these IQCs provide for fixed daily rates (which 
may include wages, overhead, general and administrative expenses, fringe 
benefits, and profit) for services and reimbursement of other direct 
costs (such as travel and transportation) at cost, then the payment 
clause at 752.232-7 shall be used in the contract.
[61 FR 39094, July 26, 1996]



                     Subpart 732.4--Advance Payments

    Source:  56 FR 67225, Dec. 30, 1991, unless otherwise noted.



732.401  Statutory authority.

    (a) Sections 635 (b) of the Foreign Assistance Act and Executive 
Order 11223, May 12, 1965, 30 FR 6635, permit the making of advance 
payments with respect to functions authorized by the Foreign Assistance 
Act. Advance payments may also be made under section 305 of the Federal 
Property and Administrative Services Act of 1949, which provides 
authority, not otherwise available to USAID, to take a paramount lien.
    (b) The Act of August 28, 1968, Public Law 85-804 does not apply to 
USAID.
[56 FR 67225, Dec. 30, 1991, as amended at 62 FR 40469, July 29, 1997]



732.402  General.

    (a)-(d) [Reserved]
    (e)(1) All U.S. Dollar advances to for-profit organizations require 
the approval of the Procurement Executive; all such approvals are 
subject to prior consultation with the USAID/W Controller.
    (2) All local currency advances to for-profit organizations require 
the approval of the Head of the Contracting Activity, after consultation 
with the Mission Controller.
[56 FR 67225, Dec. 30, 1991, as amended at 61 FR 39093, July 26, 1996]



732.403  Applicability.

    References to nonprofit contracts with nonprofit educational or 
research institutions for experimental, research and development work 
include nonprofit contracts with nonprofit institutions for: (a) 
technical assistance services provided to or for another country or 
countries, and (b) projects which concern studies, demonstrations and 
similar activities related to economic growth or the solution of social 
problems of developing countries.



732.406-70  Agency-issued letters of credit.

    This subsection provides guidance on use of USAID issued letters of 
credit (LOC) for advance payments.



732.406-71  Circumstances for use of an LOC.

    An LOC shall be used under the following circumstances:

[[Page 45]]

    (a) The contracting officer has determined that an advance payment 
is necessary and appropriate in accordance with this subpart and the 
guidance provided in FAR 32.4;
    (b) USAID has, or expects to have, a continuing relationship of at 
least one year with the organization, and the annual amount required for 
advance financing will be at least $50,000; and
    (c) The Office of Financial Management, Cash Management and Payment 
Division (FM/CMP) agrees that the LOC payment method is appropriate.
[56 FR 67225, Dec. 30, 1991, as amended at 61 FR 39093, July 26, 1996]



732.406-72  Establishing an LOC.

    (a) While the contract will provide for the use of an LOC when it is 
justified under subsection 732.406-71, the LOC is a separate agreement 
between the contractor and FM/CMP, acting on behalf of the USAID 
Controller. The terms and conditions of the LOC are established by FM/
CMP/GIB.
    (b) In order to establish or amend an LOC, the contracting officer 
shall provide FM/CMP with the following information:
    (1) The name of the Contractor;
    (2) The official 16 digit USAID contract number;
    (3) The obligated amount of the contract;
    (4) The budget plan code for the obligated funds;
    (5) The effective date and estimated completion date.
    (6) The contractor Federal Tax Identification Number.
    This information should be provided in writing to FM/CMP together 
with a request to establish or amend an LOC as early in the negotiation 
cycle as possible.
    (c) FM/CMP will prepare the LOC in accordance with USAID's LOC 
procedures; issue or amend and maintain the LOC in accordance with its 
terms and USAID procedures and regulations; and provide the contracting 
officer(s) a copy of each LOC and any other material governing its use 
at the time the LOC is issued or when it is amended or modified.
[56 FR 67225, Dec. 30, 1991, as amended at 61 FR 39093, July 26, 1996]



732.406-73  LOC contract clause.

    If payment is to be provided by LOC, the contract shall contain the 
clause in subsection 752.232-70.



732.406-74  Revocation of the LOC.

    If during the term of the contract FM/CMP believes that the LOC 
should be revoked, FM/CMP may, after consultation with the cognizant 
contracting officer(s) and GC, revoke the LOC by written notification to 
the contractor. A copy of any such revocation notice will immediately be 
provided to the cognizant contracting officer(s).



PART 733--PROTESTS, DISPUTES, AND APPEALS--Table of Contents




                         Subpart 733.1--Protests

Sec.
733.101  Definitions.
733.103-70  Protest to the agency.
733.103-71  Filing of protest.
733.103-72  Responsibilities.
733.103-73  Protests excluded from consideration.

        Subpart 733.27--USAID Procedures for Disputes and Appeals

733.270-1  Designation of Armed Services Board of Contract Appeals 
          (ASBCA) to hear and determine appeals under USAID contracts.
733.270-2  Special procedures regarding contract disputes appeals 
          promulgated pursuant to paragraph 2 of the Administrator's 
          designation.

    Authority:  Sec. 621. Pub. L. 87-195, 73 Stat. 445 (22 U.S.C. 2381), 
as amended: E.O. 12163, Sept. 29, 1979, 44 FR 56673, 3 CFR, 1979 Comp. 
p. 435.



                         Subpart 733.1--Protests

    Source:  61 FR 39094, July 26, 1996, unless otherwise noted.



733.101  Definitions.

    (a) ``Procurement Executive'' is defined in AIDAR 702.170-13.
    (b) All ``days'' referred to in this subpart are deemed to be 
``calendar days'', in accordance with FAR 33.101. In the case of USAID 
overseas offices with non-Saturday/Sunday weekend schedules, the 
official post weekend applies in lieu of Saturday and Sunday.

[[Page 46]]

    (c) All other terms defined in FAR 33.101 are used herein with the 
same meaning.



733.103-70  Protests to the agency.

    USAID follows the agency protest procedures in FAR 33.103, as 
supplemented by this section.



733.103-71  Filing of protest.

    (a) Protests must be in writing and addressed to the Contracting 
Officer for consideration by the Procurement Executive.
    (b) A protest shall include, in addition to the information required 
in FAR 33.103(d)(2), the name of the issuing Mission or office.
    (c) Material submitted by a protester will not be withheld from any 
interested party outside the government or from any government agency if 
the Procurement Executive decides to release such material, except to 
the extent that the withholding of such information is permitted or 
required by law or regulation.
[61 FR 39094, July 26, 1996; 61 FR 51235, Oct. 1, 1996]



733.103-72  Responsibilities.

    (a) Procurement Executive. The decision regarding an agency protest 
shall be made by the Procurement Executive within 30 days from the date 
a proper protest is filed unless the Procurement Executive determines 
that a longer period is necessary to resolve the protest, and so 
notifies the protester in writing. The Procurement Executive shall make 
his or her decision after personally reviewing and considering all 
aspects of the case as presented in the protest itself and in any 
documentation provided by the contracting officer, and after obtaining 
input and clearance from the Assistant General Counsel for Litigation 
and Enforcement (GC/LE). The decision shall be in writing and 
constitutes the final decision of the Agency.
    (b) Contracting Officer. The Contracting Officer is responsible for 
requesting an extension of the time for acceptance of offers as 
described in FAR 33.103(f)(2).
[61 FR 39094, July 26, 1996; 61 FR 51235, Oct. 1, 1996]



733.103-73  Protests excluded from consideration.

    (a) Contract administration. Disputes between a contractor and USAID 
are resolved pursuant to the disputes clause of the contract and the 
Contract Disputes Act of 1978.
    (b) Small business size standards and standard industrial 
classification. Challenges of established size standards or the size 
status of particular firms, and challenges of the selected standard 
industrial classification are for review solely by the Small Business 
Administration.
    (c) Procurement under Section 8(a) of the Small Business Act. 
Contracts are let under Section 8(a) of the Small Business Act to the 
Small Business Administration solely at the discretion of the 
Contracting Officer, and are not subject to review.
    (d) Protests filed in the General Accounting Office (GAO). Protests 
filed with the GAO will not be reviewed.
    (e) Procurements funded by USAID to which USAID is not a party. No 
protest of a procurement funded by USAID shall be reviewed unless USAID 
is a party to the acquisition agreement.
    (f) Subcontractor protests. Subcontractor protests will not be 
considered.
    (g) Judicial proceedings. Protests will not be considered when the 
matter involved is the subject of litigation before a court of competent 
jurisdiction or when the matter involved has been decided on the merits 
by a court of competent jurisdiction.
    (h) Determinations of responsibility by the contracting officer. A 
determination by the contracting officer that a bidder or offeror is or 
is not capable of performing a contract will not be reviewed by the 
Procurement Executive.
    (i) Small Business Certificate of Competency Program. Any referral 
made to the Small Business Administration pursuant to section 8(b)(7) of 
the Small Business Act, or any issuance of, or refusal to issue, a 
certificate of competency under that section will not be

[[Page 47]]

reviewed by the Procurement Executive.



        Subpart 733.27--USAID Procedures for Disputes and Appeals



733.270-1  Designation of Armed Services Board of Contract Appeals (ASBCA) to hear and determine appeals under USAID contracts.

    (a) The ASBCA is hereby designated the authorized representative of 
the Administrator of the U.S. Agency for International Development 
(USAID) in hearing, considering, and determining as fully and finally as 
might the Administrator, appeals by contractors from decisions on 
disputed questions taken pursuant to the provisions of contracts 
requiring the determination of such appeals by the Administrator or his/
her duly authorized representative or Board.
    (b) In acting under this designation, the ASBCA will follow such 
rules and procedures as are or may be prescribed for the conduct of 
Defense Department contract appeal cases, except for the rules entitled 
``Forwarding of Appeals'' (Rule 3) and ``Duties of the Contracting 
Officer'' (Rule 4), which subjects will be governed by procedures to be 
promulgated by the General Counsel of USAID with approval of the 
Chairman of the ASBCA.
    (c) The General Counsel of USAID will assure representation of the 
interests of the Government in proceedings before the ASBCA.
    (d) All officers and employees of USAID will cooperate with the 
ASBCA and Government counsel in the processing of appeals so as to 
assure their speedy and just determination.
[53 FR 4980, Feb. 19, 1988. Redesignated at 61 FR 39095, July 26, 1996; 
61 FR 51235, Oct. 1, 1996]



733.270-2  Special procedures regarding contract disputes appeals promulgated pursuant to paragraph 2 of the Administrator's designation.

    (a) The following rules will apply, in lieu of Rules 3 and 4(a) of 
the ASBCA, to contract dispute appeals to the Administrator of the USAID 
or his/her authorized representative which are docketed with that Board.
    (b) Rule 3 (USAID)--Forwarding of Appeals. When a notice of appeal 
in any form has been received by the contracting officer, he/she shall 
endorse thereon the date of mailing (or date of receipt, if otherwise 
conveyed) and within 10 days shall forward said notice of appeal to the 
Board with a copy to the USAID General Counsel in Washington, DC. 
Following receipt by the Board of the original notice of an appeal 
(whether through the contracting officer or otherwise), the contractor, 
the contracting officer, and the USAID General Counsel will be promptly 
advised of its receipt, and the contractor will be furnished a copy of 
these rules.
    (c) Rule 4 (USAID). Preparation, Contents, Organization, Forwarding, 
and Status of Appeal File (Supersedes Rule 4, ``Duties of Contracting 
Officer'' of the ASBCA rules in effect on April 1, 1980).
    (d) Duties of Contracting Officer. Within 30 days of receipt of an 
appeal or advice that an appeal has been filed, the contracting officer 
shall assemble and transmit to the USAID General Counsel in Washington, 
DC, two copies of all documents pertinent to the appeal, including:
    (1) The decision and findings of fact from which appeal is taken;
    (2) The contract, including specifications and pertinent amendments, 
plans and drawings;
    (3) All correspondence between the parties pertinent to the appeal, 
including the letter or letters of claim in response to which the 
decision was issued;
    (4) All transcripts of any testimony taken during the course of 
proceedings, and affidavits or statements of any witnesses on the matter 
in dispute made prior to the filing of the notice of appeal with the 
Board; and
    (5) Any additional information considered pertinent.
    (e) The General Counsel will compile the appeal file from such 
documents, which file must contain the items enumerated in paragraphs 
(d) (1) through (5) of this section and will promptly, and in any event 
within 65 days after the appeal is docketed by the Board, transmit the 
appeal file to the Board. The General Counsel will notify the appellant 
when he/she has compiled the

[[Page 48]]

appeal file, will provide him/her with a list of its contents, and will 
afford him/her an opportunity to examine the complete file at the office 
of the Board and, if the General Counsel deems it appropriate, at any 
overseas location, for the purpose of satisfying himself/herself as to 
the contents, and furnishing or suggesting any additional documentation 
deemed pertinent to the appeal. After receipt of the foregoing file, as 
it may be augmented at the time of receipt, the Board will promptly 
advise the parties.
[53 FR 4980, Feb. 19, 1988. Redesignated at 61 FR 39095, July 26, 1996; 
61 FR 51235, Oct. 1, 1996; 62 FR 40469, July 29, 1997]

[[Page 49]]



             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING





PART 734--MAJOR SYSTEM ACQUISITION--Table of Contents




    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445 (22 U.S.C. 2381), 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673, 3 CFR, 1979 Comp., 
p. 435.



734.002-70  USAID policy.

    In order for an USAID acquisition to be considered a major system 
acquisition it must meet the criteria of OMB Circular A-109 and FAR part 
34, and must have an estimated value of $15 million or more during the 
first year of the contract. All major systems acquisition must be 
approved in advance by the Procurement Executive.
[55 FR 39976, Oct. 1, 1990]



PART 736--CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS--Table of Contents




               Subpart 736.6--Architect-Engineer Services

Sec.
736.602-2  Evaluation boards.
736.602-3  Evaluation board functions.
736.602-4  Selection authority.
736.602-5  Short selection process for procurements not to exceed the 
          simplified acquisition threshold.
736.603  Collecting data on and appraising firms' qualifications.
736.605  Government cost estimate for architect-engineer work.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13254, Apr. 3, 1984, unless otherwise noted.



               Subpart 736.6--Architect-Engineer Services



736.602-2  Evaluation boards.

    (a)-(b) [Reserved]
    (c) Each evaluation board will include a representative of the 
Contracting Officer and, as appropriate, the cognizant bureau.
[54 FR 46391, Nov. 3, 1989]



736.602-3  Evaluation board functions.

    Agency architect-engineer evaluation boards shall perform the 
following functions:
    (a) Prepare a selection memorandum recommending no less than three 
firms which are considered most highly qualified to perform the required 
services for submission to the head of the contracting activity for his/
her approval. This selection memorandum shall include the information 
specified in 736.602-3(c).
    (b) In evaluating architect-engineer firms, the architect-engineer 
evaluation board shall apply the following criteria, other criteria 
established by Agency regulations, and any criteria set forth in the 
public notice on a particular contract:
    (1) Specialized experience of the firm (including each member of 
joint venture or association) with the type of service required;
    (2) Capacity of the firm to perform the work (including any 
specialized services) within the time limitations;
    (3) Past record of performance on contracts with USAID or other 
Government agencies and private industry with respect to such factors as 
control of costs, quality of work, and ability to meet schedules, to the 
extent such information is available;
    (4) Ability to assign an adequate number of qualified key personnel 
from the organization, including a competent supervising representative 
having considerable experience in responsible positions on work of a 
similar nature;
    (5) The portions of the work the architect-engineer is able to 
perform with its own forces when required;
    (6) Ability of the architect-engineer to furnish or to obtain 
required materials and equipment;
    (7) If the geographical or topographical aspects of the project are 
deemed vital, familiarity with the locality where the project is 
situated;
    (8) Financial capacity;
    (9) Responsibility of the architect-engineer under standards 
provided in FAR subpart 9.1. No contract may be

[[Page 50]]

awarded to a contractor that does not meet these standards;
    (10) Volume of work previously awarded to the firm by the Agency, 
with the object of effecting an equitable distribution of architect-
engineer contracts among qualified firms. Each architect-engineer 
evaluation board shall give favorable consideration, to the fullest 
extent practicable to the most highly qualified firms that have not had 
prior experience on Government projects (including small business firms 
and firms owned by the socially and/or economically deprived).
    (c) The evaluation board shall prepare a selection memorandum for 
the approval of the head of the contracting activity. The selection 
memorandum will be signed by the board chairman and cleared by each 
board member. The selection memorandum shall include the following 
information:
    (1) A listing by name of all firms reviewed by the board;
    (2) A listing of the evaluation criteria applied;
    (3) An analysis of the selection showing the rationale for the 
board's recommendation;
    (4) The board's recommendation of the three most highly qualified 
firms, in order of preference;
    (5) An independent Government cost estimate. The evaluation board 
shall require the project engineer to develop an independent Government 
estimate of the cost of the required architect-engineer services. 
Consideration shall be given to the estimated value of the services to 
be rendered, the scope, complexity, and the nature of the project and 
the estimated costs expected to be generated by the work. The 
independent Government estimate shall be revised as required during 
negotiations to correct noted deficiencies and reflect changes in or 
clarification of, the scope of the work to be performed by the 
architect-engineer. A cost estimate based on the application of 
percentage factors to cost estimates of the various segments of the work 
involved, e.g., construction project, may be developed for comparison 
purposes, but such a cost estimate shall not be used as a substitute for 
the independent Government estimate.



736.602-4  Selection authority.

    (a) The head of the contracting activity or his/her authorized 
designee shall review the selection memorandum and shall either approve 
it or return it to the board for reconsideration for specified reasons.
    (b) Approval of the selection memorandum by the head of the 
contracting activity or his/her authorized designee shall serve as 
authorization for the contracting office to commence negotiation.



736.602-5  Short selection process for procurements not to exceed the simplified acquisition threshold.

    References to FAR 36.602-3 and 36.602-4 contained in FAR 36.602-5 
shall be construed as references to 736.602-3 and 736.602-4 of this 
subpart.
[49 FR 13254, Apr. 3, 1984, as amended at 61 FR 39095, July 26, 1996]



736.603  Collecting data on and appraising firms' qualifications.

    An USAID Consultant Registry Information System (ACRIS) is 
maintained in Washington by the USAID Office of Small and Disadvantaged 
Business Utilization. Architect-engineers wishing to perform contracts 
for USAID should file the appropriate form with that office, as provided 
in section 705.002. Procurements are publicized in the Commerce Business 
Daily, as provided in FAR part 5.
[49 FR 13254, Apr. 3, 1984, as amended at 52 FR 21059, June 4, 1987; 53 
FR 50631, Dec. 16, 1988]



736.605  Government cost estimate for architect-engineer work.

    See 736.602-3(c)(5).



PART 737 [RESERVED]




[[Page 51]]



                    SUBCHAPTER G--CONTRACT MANAGEMENT





PART 742--CONTRACT ADMINISTRATION--Table of Contents




    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.



                   Subpart 742.7--Indirect Cost Rates



742.770  Negotiated indirect cost rate agreement.

    Except for educational institutions having a cognizant agency (as 
defined in OMB Circular A-88, 44 FR 70094, 12/5/79) other than USAID, 
USAID may establish negotiated overhead rates in a Negotiated Indirect 
Cost Rate Agreement, executed by both parties. The Negotiated Indirect 
Cost Rate Agreement is automatically incorporated in each contract 
between the parties and shall specify: (a) The final rate(s), (b) the 
base(s) to which the rate(s) apply, (c) the period(s) for which the 
rate(s) apply, (d) the items treated as direct costs, and (e) the 
contract(s) to which the rate(s) apply. The Negotiated Indirect Cost 
Rate Agreement shall not change any monetary ceiling, obligation, or 
specific cost allowance or disallowance provided for in each contract 
between the parties.
[49 FR 13256, Apr. 3, 1984; 53 FR 50631, Dec. 16, 1988]



PART 749--TERMINATION OF CONTRACTS--Table of Contents




                    Subpart 749.1--General Principles

Sec.
749.100  Scope of subpart.
749.111  Review of proposed settlements.
749.111-70  Termination settlement review boards.
749.111-71  Required review and approval.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13256, Apr. 3, 1984, unless otherwise noted.



                    Subpart 749.1--General Principles



749.100  Scope of subpart.

    The Foreign Aid and Related Agencies Appropriation Act, 1963, and 
subsequent appropriation Acts, have imposed the following requirement:

    None of the funds appropriated or made available pursuant to this 
Act for carrying out the Foreign Assistance Act of 1961, as amended, may 
be used for making payments on any contract for procurement to which the 
United States is a party entered into after the date of enactment of 
this Act which does not contain a provision authorizing the termination 
of such contract for the convenience of the United States.


See, for example, section 110 of the Foreign Assistance and Related 
Agencies Appropriation Act, 1965.



749.111  Review of proposed settlements.



749.111-70  Termination settlement review boards.

    (a) The USAID Settlement Review Board shall be composed of the 
following members or their delegates (except as provided under 749.111-
71(b)):
    (1) Procurement Executive;
    (2) Controller;
    (3) General Counsel.
    (b) The Procurement Executive or his/her delegate shall be 
designated as chairman of the board. Delegate members of the board shall 
have broad business and contracting experience and shall be senior USAID 
officials. Each member or his/her delegate must be in attendance in 
order to conduct business, and the board shall act by majority vote. No 
individual shall serve as a member of a board for the review of a 
proposed settlement if he/she has theretofore reviewed, approved or 
disapproved or recommended approval, disapproval or other action with 
respect to any substantive element of such settlement proposal.
    (c) The chairman shall appoint a nonvoting recorder who shall be 
responsible for receiving cases, scheduling

[[Page 52]]

and recording the proceedings at meetings, maintaining a log of all 
cases received by him/her for the board, and other duties as assigned by 
the board.



749.111-71  Required review and approval.

    (a) When required. The USAID Settlement Review Board shall receive 
and approve all USAID/W and Mission proposed settlements or 
determinations if:
    (1) The amount of settlement, by agreement or determination, 
involves $100,000 or more;
    (2) The settlement or determination is limited to adjustment of the 
fee of a cost-reimbursement contract or subcontract and: (i) In the case 
of complete termination, the fee, as adjusted, with respect to the 
terminated portion of the contract or subcontract is $100,000 or more; 
or (ii) in the case of a partial termination, the fee, as adjusted, with 
respect to the terminated portion of the contract or subcontract is 
$100,000 or more;
    (3) The head of the contracting activity concerned determines that a 
review of a specific case or class of cases is desirable; or
    (4) The contracting officer, in his/her discretion, desires review 
by the board.
    (b) Level of review. Proposed settlements in excess of $5 million 
shall be reviewed and approved by a board consisting of the Procurement 
Executive, the General Counsel, and the Controller, without power of 
redelegation.
    (c) Submission of information. The contracting officer shall submit 
to the board a statement of the proposed settlement agreement or 
determination, supported by such detailed information as is required for 
an adequate review. This information should normally include copies of: 
(1) The contractor's or subcontractor's settlement proposal, (2) the 
audit report, (3) the property disposal report and any required 
approvals in connection therewith, and (4) the contracting officer's 
memorandum explaining the settlement. The board may, in its discretion, 
require the submission of additional information.
[49 FR 13256, Apr. 3, 1984, as amended at 57 FR 5236, Feb. 13, 1992; 59 
FR 33446, June 29, 1994]



PART 750--EXTRAORDINARY CONTRACTUAL ACTIONS--Table of Contents




Sec.
750.000  Scope of part.

                        Subpart 750.70 [Reserved]

  Subpart 750.71--Extraordinary Contractual Actions To Protect Foreign 
                  Policy Interests of the United States

750.7100  Scope of subpart.
750.7101  Authority.
750.7102  General policy.
750.7103  Definitions.
750.7104  Types of actions.
750.7105  Approving authorities.
750.7106  Standards for deciding cases.
750.7106-1  General.
750.7106-2  Amendments without consideration.
750.7106-3  Mistakes.
750.7106-4  Informal commitments.
750.7107  Limitations upon exercise of authority.
750.7108  Contractual requirements.
750.7109  Submission of requests by contractors.
750.7109-1  Filing requests.
750.7109-2  Form of requests by contractors.
750.7109-3  Facts and evidence.
750.7110  Processing cases.
750.7110-1  Investigation.
750.7110-2  Office of General Counsel coordination.
750.7110-3  Submission of cases to the Procurement Executive.
750.7110-4  Processing by Procurement Executive.
750.7110-5  Contract files.
750.7110-6  Inter-agency coordination.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13257, Apr. 3, 1984, unless otherwise noted.



750.000  Scope of part.

    USAID is not among the agencies named in the Act or authorized by 
the President to take actions under it; however, see Subpart 750.71--
Extraordinary Contractual Actions to Protect Foreign Policy Interests of 
the United States.

[[Page 53]]



                        Subpart 750.70 [Reserved]



  Subpart 750.71--Extraordinary Contractual Actions To Protect Foreign 
                  Policy Interests of the United States



750.7100  Scope of subpart.

    This subpart sets forth the standards and the procedures for 
disposition of requests for extraordinary contractual actions under 
Executive Order 11223.



750.7101  Authority.

    (a) Under section 633 of the Foreign Assistance Act of 1961, 75 
Stat. 454 (22 U.S.C. 2933), as amended; Executive Order 11223, dated May 
12, 1965 (30 FR 6635), as amended; Executive Order 12163, dated 
September 29, 1979 (44 FR 56673), as amended; and International 
Development Cooperation Agency Delegation of Authority No. 1, dated 
October 1, 1979 (44 FR 57521), as amended, the Administrator of the U.S. 
Agency for International Development has been granted authority to 
provide extraordinary contractual relief. The Authority is set forth in 
sections 3 and 4 of Executive Order 11223, as follows:

    Section 3. With respect to cost-type contracts heretofore or 
hereafter made with non-profit institutions under which no fee is 
charged or paid, amendments or modifications of such contracts may be 
made with or without consideration and may be utilized to accomplish the 
same things as any original contract could have accomplished, 
irrespective of the time or circumstances of the making, or of the form 
of the contract amended or modified, or of the amending or modifying 
contract and irrespective of rights which may have accrued under the 
contract or the amendments or modifications thereof.
    Section 4. With respect to contracts heretofore or hereafter made, 
other than those described in section 3 of this order, amendments and 
modifications of such contracts may be made with or without 
consideration and may be utilized to accomplish the same things as any 
original contract could have accomplished, irrespective of the time or 
circumstances of the making, or the form of the contract amended or 
modified, or of the amending or modifying contract, and irrespective of 
rights which may have accrued under the contract or the amendments or 
modifications thereof, if the Secretary of State or the Director of the 
United States International Development Cooperation Agency (with respect 
to functions vested in or delegated to Director) determines in each case 
that such action is necessary to protect the foreign policy interests of 
the United States.

    (b) The authority delegated to the Director of the International 
Development Cooperation Agency under Executive Order 11223 has been 
redelegated to the Administrator, U.S. Agency for International 
Development.
[49 FR 49472, Dec. 20, 1984, as amended at 62 FR 40469, July 29, 1997]



750.7102  General policy.

    Extra-contractual claims arising from foreign assistance contracts 
will be processed in accordance with this subpart, which is similar to 
that utilized to process claims for extraordinary relief under FAR Part 
50, as modified to meet the circumstances involved under the Foreign 
Assistance Act and the different authority involved.



750.7103  Definitions.

    (a) The term approving authority as used in this subpart means an 
officer or official having been delegated authority to approve actions 
under the Executive Order. This authority is distinguished from 
authority to take appropriate contractual action pursuant to such 
approval.
    (b) The term the Executive Order shall mean Executive Order 11223 
(30 FR 6635) as amended, unless otherwise stated.
    (c) The term the Act shall mean the Foreign Assistance Act of 1961, 
as amended.
[49 FR 13257, Apr. 3, 1984, as amended at 49 FR 49472, Dec. 20, 1984]



750.7104  Types of actions.

    Three types of actions may be taken by or pursuant to the direction 
of an approving authority under the Executive Order. These are 
contractual adjustments such as amendments without consideration, 
correction of mistakes, and formalization of informal commitments.



750.7105  Approving authorities.

    All authority to approve actions under this subpart has been 
delegated to the Procurement Executive.
[50 FR 16086, Apr. 24, 1985]

[[Page 54]]



750.7106  Standards for deciding cases.



750.7106-1  General.

    The mere fact that losses occur under a Government contract is not, 
by itself, a sufficient basis for the exercise of the authority 
conferred by the Executive Order. Whether, in a particular case, 
appropriate action such as amendment without consideration, correction 
of a mistake or ambiguity in a contract, or formalization of an informal 
commitment, will protect the foreign policy interests of the United 
States is a matter of sound judgment to be made on the basis of all of 
the facts of such case. Although it is obviously impossible to predict 
or enumerate all the types of cases with respect to which action may be 
appropriate, examples of certain cases or types of cases where action 
may be proper are set forth in sections 750.7106-2 through 750.7106-4. 
Even if all of the factors contained in any of the examples are present, 
other factors or considerations in a particular case may warrant denial 
of the request. These examples are not intended to exclude other cases 
where the approving authority determines that the circumstances warrant 
action.



750.7106-2  Amendments without consideration.

    (a) Where an actual or threatened loss under a foreign assistance 
contract, however caused, will impair the productive ability of a 
contractor whose continued performance of any foreign assistance 
contract or whose continued operation as a source of supply is found to 
be essential to protect the foreign policy interests of the United 
States, the contract may be adjusted but only to the extent necessary to 
avoid such impairment to the contractor's productive ability.
    (b) Where a contractor suffers a loss (not merely a diminution of 
anticipated profits) on a foreign assistance contract as a result of 
Government action, the character of the Government action will generally 
determine whether any adjustment in the contract will be made and its 
extent. Where the Government action is directed primarily at the 
contractor and is taken by the Government in its capacity as the other 
contracting party, the contract may be adjusted if fairness so requires; 
thus where such Government action, although not creating any liability 
on its part, increases the cost of performance, considerations of 
fairness may make appropriate some adjustment in the contract.



750.7106-3  Mistakes.

    A contract may be amended or modified to corrrect or mitigate the 
effect of a mistake, including the following examples:
    (a) A mistake or ambiguity which consists of the failure to express 
or to express clearly in the written contract the agreements as both 
parties understood them;
    (b) A mistake on the part of the contractor which is so obvious that 
it was or should have been apparent to the contracting officer; and
    (c) A mutual mistake as to a material fact.

Amending contracts to correct mistakes with the least possible delay 
normally will protect the foreign policy interests of the United States 
by expediting the procurement program and by giving contractors proper 
assurance that such mistakes will be corrected expeditiously and fairly.



750.7106-4  Informal commitments.

    Informal commitments may be formalized under certain circumstances 
to permit payment to persons who have taken action without a formal 
contract; for example, where any person, pursuant to written or oral 
instructions from an officer or official of the Agency and relying in 
good faith upon the apparent authority of the officer or official to 
issue such instructions, has arranged to furnish or has furnished 
property or services to the agency and/or to a foreign assistance 
contractor or subcontractor without formal contractual coverage for such 
property or services. Formalization of commitments under such 
circumstances normally will protect the foreign policy interests of the 
United States by assuring persons that they will be treated fairly and 
paid expeditiously.

[[Page 55]]



750.7107  Limitations upon exercise of authority.

    (a) The Executive Order is not authority for:
    (1) The use of the cost-plus-a-percentage-of-cost system of 
contracting;
    (2) The making of any contract in violation of existing law relating 
to limitation on profit or fees;
    (3) The waiver of any bid, payment performance or other bond 
required by law.
    (b) No amendments, or modifications shall be entered into under the 
authority of the Executive Order:
    (1) Unless, with respect to cases falling within Section 4 of the 
Executive Order, a finding is made that the action is necessary to 
protect the foreign policy interests of the United States;
    (2) Unless other legal authority in the Agency is deemed to be 
lacking or inadequate;
    (3) Except within the limits of the amounts appropriated and the 
statutory contract authorization.
    (c) No contract shall be amended or modified unless the request 
therefor has been filed before all obligations (including final payment) 
under the contract have been discharged.
    (d) No informal commitment shall be formalized unless:
    (1) A request for payment has been filed within six months after 
arranging to furnish or furnishing property or services in reliance upon 
the commitment;
    (2) USAID has received the services satisfactorily performed, or has 
accepted property furnished in reliance on the commitment;
    (3) The USAID employees alleged to have made the informal commitment 
have accepted responsibility for making the informal commitment in 
question; and
    (4) USAID has taken appropriate action to prevent recurrence.
[49 FR 13257, Apr. 3, 1984, as amended at 50 FR 16088, Apr. 24, 1985; 53 
FR 4982, Feb. 19, 1988]



750.7108  Contractual requirements.

    Every contract amended or modified pursuant to this subpart shall 
contain:
    (a) A citation of the Act and Executive Order.
    (b) A brief statement of the circumstances justifying the action;
    (c) A recital of the finding, with respect to cases falling within 
Section 4 of the Executive Order, that the action is necessary to 
protect the foreign policy interests of the United States.



750.7109  Submission of requests by contractors.



750.7109-1  Filing requests.

    Any person (hereinafter called the ``contractor'') seeking an 
adjustment under standards set forth in 750.7106 may file a request in 
duplicate with the cognizant contracting officer or his/her duly 
authorized representative. If such filing is impracticable, requests 
will be deemed to be properly filed if filed with the Chief of the 
Office of Procurement, Evaluation Division (M/OP/E) for forwarding to 
the cognizant contracting officer.
[49 FR 13257, Apr. 3, 1984, as amended at 50 FR 50303, Dec. 10, 1985; 55 
FR 6802, Feb. 27, 1990; 56 FR 67225, Dec. 30, 1991; 59 FR 33446, June 
29, 1994]



750.7109-2  Form of requests by contractors.

    The contractor's request shall normally consist of a letter to the 
contracting officer providing the information specified in FAR 50.303.



750.7109-3  Facts and evidence.

    The contracting officer or the approving authority may, where 
considered appropriate, request the contractor to furnish the facts and 
evidence as described in FAR 50.304.
[49 FR 13257, Apr. 3, 1984, as amended at 62 FR 40469, July 29, 1997]



750.7110  Processing cases.



750.7110-1  Investigation.

    The Evaluation Division of the Office of Procurement (M/OP/E) shall 
be responsible for assuring that the case prepared by the cognizant 
contracting officer makes a thorough investigation of all facts and 
issues relevant to each situation. Facts and evidence shall be obtained 
from contractor and Government personnel and shall include signed 
statements of material facts

[[Page 56]]

within the knowledge of the individuals where documentary evidence is 
lacking and audits where considered necessary to establish financial or 
cost related facts. The investigation shall establish the facts 
essential to meet the standards for deciding the particular case and 
shall address the limitations upon exercise of the Procurement 
Executive's authority to approve the request.
[62 FR 40469, July 29, 1997]



750.7110-2  Office of General Counsel coordination.

    Prior to the submission of a case to the Procurement Executive 
recommending extraordinary contractual relief, the claim shall be fully 
developed by the cognizant contracting officer and concurrences or 
comments shall be obtained from the Office of General Counsel for the 
proposed relief to be granted. Such concurrences or comments shall be 
incorporated in or accompany the action memorandum submitted for 
consideration to the Procurement Executive in accordance with 750.7110-
3.
[62 FR 40469, July 29, 1997]



750.7110-3  Submission of cases to the Procurement Executive.

    Cases to be submitted for consideration by the Procurement Executive 
shall be prepared and forwarded by the cognizant contracting officer 
through M/OP/E to the Procurement Executive by means of an action 
memorandum. M/OP/E will review the action memorandum for accuracy and 
completeness. The action memorandum shall provide for approval or 
disapproval by the Procurement Executive of the disposition recommended 
by the contracting officer. The action memorandum shall address:
    (a) The nature of the case;
    (b) The basis for authority to act under section 750.7101;
    (c) The findings of fact essential to the case (see 750.7109-3) 
arranged chronologically with cross references to supporting enclosures;
    (d) The conclusions drawn from applying the standards for deciding 
cases, as set forth in 750.7106, to the findings of fact;
    (e) Compliance with the limitations upon exercise of authority, as 
set forth in section 750.7107 (for informal commitments, include 
statements addressing each of the limitations in paragraph (d) of 
750.7107):
    (f) Concurrences or comments obtained from the Office of General 
Counsel;
    (g) Verification of funds availability and the contracting officer's 
determination of cost/price reasonableness when the disposition 
recommended requires payment to a contractor;
    (h) The disposition recommended and, if contractual action is 
recommended with respect to cases falling within Section 4 of the 
Executive Order, the opinion of the contracting officer that such action 
is necessary to protect the foreign policy interest of the United 
States; and
    (i) The action memorandum shall enclose all evidentiary materials, 
including the reports and comments of all cognizant Government or other 
officials, and a copy of the contractor's request. The action memorandum 
should provide the following information related to the contractor's 
request, as applicable:
    (1) Date of request;
    (2) Date request received by USAID:
    (3) Contract number;
    (4) Contractor's name and address;
    (5) Name, address, and phone number of contractor's representative;
    (6) Name, office symbol, and phone number of cognizant contracting 
officer;
    (7) Amount of request.
[62 FR 40469, July 29, 1997]



 750.7110-4  Processing by Procurement Executive.

    When the action memorandum has been determined to be as accurate and 
complete as possible and has been prepared in accordance with this 
subpart, M/OP/E will forward the action memorandum to the Procurement 
Executive. The Procurement Executive will sign and date the action 
memorandum indicating approval or disapproval of the disposition 
recommended by the contracting officer.
[62 FR 40469, July 29, 1997]

[[Page 57]]



750.7110-5  Contract files.

    The fully executed action memorandum indicating approval/disapproval 
and a copy of the contractual document implementing any approved 
contractual action shall be placed in the contract file.
[62 FR 40469, July 29, 1997; 62 FR 47532, Sept. 9, 1997]



750.7110-6  Inter-agency coordination.

    (a) General. Where a case involves matters of interest to more than 
one department or agency, USAID should maintain liaison with other 
departments and agencies of the Government and take such joint action as 
may be proper under the circumstances, including holding joint meetings.
    (b) Cases involving funds of other departments or agencies. Requests 
for adjustment within any category, involving the funds of another 
department or agency, shall not be approved by USAID until advice is 
requested and received from the department or agency whose funds are 
involved.

[[Page 58]]



                     SUBCHAPTER H--CLAUSES AND FORMS





PART 752--SOLICITATION PROVISIONS AND CONTRACT CLAUSES--Table of Contents




             Subpart 752.2--Texts of Provisions and Clauses

Sec.
752.200  Scope of subpart.
752.202-1  Definitions.
752.204-2  Security requirements.
752.209-71  Organizational conflicts of interest discovered after award.
752.211-70  Language and measurement.
752.219-8  Utilization of small business concerns and small 
          disadvantaged business concerns.
752.225-9  Buy American Act--Trade Agreements Act--Balance of Payments 
          Program.
725.225-70  Source, origin and nationality requirements.
725.225-71  Local procurement.
752.226-1  Determination of status as disadvantaged enterprise.
752.226-2  Subcontracting with disadvantaged enterprises.
752.226-3  Limitation on subcontracting.
752.228-3  Worker's compensation insurance (Defense Base Act).
752.228-7  Insurance--liability to third persons
752.228-9  Cargo insurance.
752.228-70  Medical Evacuation (MEDEVAC) Services.
752.229-70  Federal, state and local taxes.
752.232-7  Payments under time-and-materials and labor-hour contracts.
752.232-70  Letter of credit advance payment.
752.245-70  Government property--USAID reporting requirements.
752.245-71  Title to and care of property.

             Subpart 752.70--Texts of USAID Contract Clauses

752.7000  Scope of subpart.
752.7001  Biographical data.
752.7002  Travel and transportation.
752.7003  Documentation for payment.
752.7004  Emergency locator information.
752.7005  [Reserved]
752.7006  Notices.
752.7007  Personnel compensation.
752.7008  Use of Government facilities or personnel.
752.7009  Marking.
752.7010  Conversion of U.S. dollars to local currency.
752.7011  Orientation and language training.
752.7012  Protection of the individual as a research subject.
752.7013  Contractor-mission relationships.
752.7014  Notice of changes in travel regulations.
752.7015  Use of pouch facilities.
752.7016  Family planning and population assistance activities.
752.7017  [Reserved]
752.7018  Health and accident coverage for USAID participant trainees.
752.7019  Participant training.
752.7020  [Reserved]
752.7021  Changes in tuition and fees.
752.7022  Conflicts between contract and catalog.
752.7023  Required visa form for USAID participants.
752.7024  Withdrawal of students.
752.7025  Approvals.
752.7026  Reports.
752.7027  Personnel.
752.7028  Differential and allowances.
752.7029  Post privileges.
752.7030  Inspection trips by contractor's officers and executives.
752.7031  Leave and holidays.
752.7032  International travel approval and notification requirements.
752.7033  Physical fitness.
752.7034  Acknowledgement and disclaimer.
752.7035  Public notices.

           Subpart 752.3-70--USAID Clause Matrices [Reserved]

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) 
as amended; E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., 
p. 435.

    Source:  49 FR 13259, Apr. 3, 1984, unless otherwise noted.



             Subpart 752.2--Texts of Provisions and Clauses



752.200  Scope of subpart.

    None of the clauses specified in this subpart are for use in USAID 
personal services contracts. For personal services contract clauses, see 
AIDAR Appendix D--Direct USAID Contracts with U.S. Citizens or U.S. 
Residents for Personal Services Abroad and AIDAR Appendix J--Direct 
USAID Contracts with Cooperating Country Nationals and with Third 
Country Nationals for Personal Services Abroad.
[49 FR 13259, Apr. 3, 1984, as amended at 51 FR 11450, Apr. 3, 1986; 51 
FR 12706, Apr. 15, 1986; 57 FR 5236, Feb. 13, 1992; 62 FR 40469, July 
29, 1997]

[[Page 59]]



752.202-1  Definitions.

    (a) As prescribed in 702.270 and in FAR Subpart 2.2, USAID contracts 
use the Definitions clause in FAR 52.202-1 and its Alternate I, as 
appropriate, and the following additional definitions.
    (b) Alternate 70. For use in all USAID contracts. Use in addition to 
the clause in FAR 52.202-1.

   USAID Definitions Clause--General Supplement for Use in All USAID 
                          Contracts (Jan. 1990)

    (a) USAID shall mean the U.S. Agency for International Development.
    (b) Administrator shall mean the Administrator or the Deputy 
Administrator of USAID.
    (c) When this contract is with an educational institution Campus 
Coordinator shall mean the representative of the Contractor at the 
Contractor's home institution, who shall be responsible for coordinating 
the activities carried out under the contract.
    (d) When this contract is with an educational institution Campus 
Personnel shall mean representatives of the Contractor performing 
services under the contract at the Contractor's home institution and 
shall include the Campus Coordinator.
    (e) Consultant shall mean any especially well qualified person who 
is engaged, on a temporary or intermittent basis to advise the 
Contractor and who is not an officer or employee of the Contractor who 
performs other duties for the Contractor.
    (f) Contractor employee shall mean an employee of the Contractor 
assigned to work under this contract.
    (g) Cooperating Country or Countries shall mean the foreign country 
or countries in or for which services are to be rendered hereunder.
    (h) Cooperating Government shall mean the government of the 
Cooperating Country.
    (i) Federal Acquisition Regulations (FAR), when referred to herein 
shall include U.S. Agency for International Development Acquisition 
Regulations (AIDAR).
    (j) Government shall mean the United States Government.
    (k) Mission shall mean the United States AID Mission to, or 
principal USAID office in, the Cooperating Country.
    (l) Mission Director shall mean the principal officer in the Mission 
in the Cooperating Country, or his/her designated representative.

    (c) Alternate 71. For use in USAID contracts with an educational 
institution for participant training. Use in addition to the clauses in 
FAR 52.202-1 and in 752.202-1(b) of this chapter.

 USAID Definitions Clause--Supplement for Contracts With an Educational 
            Institution for Participant Training (Apr. 1984)

    (a) Catalog shall mean any medium by which the Institution publicly 
announces terms and conditions for enrollment in the Institution, 
including tuition and fees to be charged. This includes ``bulletins,'' 
``announcements,'' or any other similar word the Institution may use.
    (b) Director shall mean the individual who fills the USAID position 
of Director, Office of International Training, or his/her authorized 
representative acting within the limits of his/her authority.
    (c) Fees shall mean those applicable charges directly related to 
enrollment in the Institution. This shall not include any permit charge 
(e.g., parking, vehicle registration), or charges for services of a 
personal nature (e.g., food, housing, laundry) unless specifically 
called for in this contract.
    (d) Institution shall mean the educational institution providing 
services hereunder. The terms ``Institution'' and ``Contractor'' are 
synonymous.
    (e) Tuition shall mean the amount of money charged by an institution 
for instruction, not including fees as described in this section.

    (d) Alternate 72. For use in all USAID contracts which involve any 
performance overseas. Use in addition to the clauses in FAR 52.202-1 and 
in 752.202-1(b) of this chapter.

   USAID Definitions Clause--Supplement for USAID Contracts Involving 
                    Performance Overseas (Dec. 1986)

    (a) Contractor's Chief of Party shall mean the representative of the 
Contractor in the Cooperating Country who shall be responsible for 
supervision of the performance of all duties undertaken by the 
Contractor in the Cooperating Country.
    (b) Cooperating Country National (CCN) employee means an individual 
who meets the citizenship requirements of 48 CFR 702.170-5 and is hired 
while residing outside the United States for work in a cooperating 
country.
    (c) Dependents shall mean:
    (1) Spouse;
    (2) Children (including step and adopted children) who are unmarried 
and under 21 years of age or, regardless of age, are incapable of self 
support.
    (3) Parents (including step and legally adoptive parents), of the 
employee or of the spouse, when such parents are at least 51 percent 
dependent on the employee for support; and
    (4) Sisters and brothers (including step or adoptive sisters or 
brothers) of the employee, or of the spouse, when such sisters and

[[Page 60]]

brothers are at least 51 percent dependent on the employee for support, 
unmarried and under 21 years of age, or regardless of age, are incapable 
of self support.
    (d) Local currency shall mean the currency of the Cooperating 
Country.
    (e) Regular employee shall mean a Contractor employee appointed to 
serve one year or more in the Cooperating Country.
    (f)Short-term employee shall mean a Contractor employee appointed to 
serve less than one year in the Cooperating Country.
    (g) Third Country National (TCN) employee means an individual who 
meets the citizenship requirements of 48 CFR 702.170-15 and is hired 
while residing outside the United States for work in a Cooperating 
Country.
[49 FR 13259, Apr. 3, 1984, as amended at 52 FR 4145, Feb. 10, 1987; 52 
FR 38098, Oct. 14, 1987; 55 FR 6802, Feb. 27, 1990]



752.204-2  Security requirements.

    Pursuant to the Uniform State/USAID/USIA Regulations (Volume 12, 
Foreign Affairs Manual, Chapter 540), USAID applies the safeguards 
applicable to ``Confidential'' information to administratively 
controlled information designated as ``Sensitive But Unclassified''. 
Therefore, when the clause in FAR 52.204-2 is used in USAID contracts, 
pursuant to 704.405, paragraph (a) of the clause is revised as follows:

    (a) This clause applies to the extent that this contract involves 
access to classified (`Confidential', `Secret', or `Top Secret'), or 
administratively controlled (`Sensitive But Unclassified') information.
[49 FR 13259, Apr. 3, 1984, as amended at 49 FR 33668, Aug. 24, 1984; 62 
FR 40469, July 29, 1997]



752.209-71  Organizational conflicts of interest discovered after award.

    As prescribed in 709.507-2, for use if one of the FAR organizational 
conflict of interest solicitation clauses, FAR 52.209-7 or 52.209-8, is 
used.

 Organizational Conflicts of Interest Discovered After Award (June 1993)

    (a) The Contractor agrees that, if after award it discovers either 
an actual or potential organizational conflict of interest with respect 
to this contract, it shall make an immediate and full disclosure in 
writing to the Contracting Officer which shall include a description of 
the action(s) which the Contractor has taken or proposes to take to 
avoid, eliminate or neutralize the conflict.
    (b) The Contracting Officer shall provide the contractor with 
written instructions concerning the conflict. USAID reserves the right 
to terminate the contract if such action is determined to be in the best 
interest of the Government.

                             (End of clause)

[58 FR 42255, Aug. 9, 1993]



752.211-70  Language and measurement.

    The following clause shall be used in all USAID-direct contracts.

                  Language and Measurement (June 1992)

    (a) The English language shall be used in all written communications 
between the parties under this contract with respect to services to be 
rendered and with respect to all documents prepared by the contractor 
except as otherwise provided in the contract or as authorized by the 
contracting officer.
    (b) Wherever measurements are required or authorized, they shall be 
made, computed, and recorded in metric system units of measurement, 
unless otherwise authorized by USAID in writing when it has found that 
such usage is impractical or is likely to cause U.S. firms to experience 
significant inefficiencies or the loss of markets. Where the metric 
system is not the predominant standard for a particular application, 
measurements may be expressed in both the metric and the traditional 
equivalent units, provided the metric units are listed first.

                             (End of clause)

[57 FR 23321, June 3, 1992. Redesignated at 61 FR 39095, July 26, 1996.]



752.219-8  Utilization of small business concerns and small disadvantaged business concerns.

    The Foreign Assistance Act calls for USAID to give small businesses 
an opportunity to provide supplies and services for foreign assistance 
projects. To help USAID meet this obligation, the following paragraph is 
to be added to the clause prescribed in FAR 19.708(a):

    USAID small business provision. To permit USAID, in accordance with 
the small business provisions of the Foreign Assistance Act, to give 
small business firms an opportunity to participate in supplying 
equipment supplies and services financed under this contract, the 
Contractor shall, to the maximum extent possible, provide the following 
information to the Office of Small and Disadvantaged Business 
Utilization (OSDBU), USAID, Washington, DC 20523-1414, at least 45 days 
prior to placing any order in excess

[[Page 61]]

of the simplified acquisition threshold except where a shorter time is 
requested of, and granted by OSDBU:
    (1) Brief general description and quantity of commodities or 
services;
    (2) Closing date for receiving quotations or bids; and
    (3) Address where invitations or specifications may be obtained.
[49 FR 13259, Apr. 3, 1984, as amended at 52 FR 21059, June 4, 1987; 56 
FR 2699, Jan. 24, 1991; 61 FR 39095, July 26, 1996; 62 FR 40469, July 
29, 1997]



752.225-9  Buy American Act--Trade Agreements Act--Balance of Payments Program.

    The clause prescribed by FAR 25.408(a)(2) is not generally included 
in USAID contracts when more stringent source requirements are stated in 
the contract or when inclusion is not appropriate under FAR 25.403, or 
725.403 of this chapter. (See Executive Order 11223, dated May 12, 1965, 
30 FR 6635.) The clause setting forth USAID's source restrictions is 
shown in section 752.225-70.
[49 FR 13259, Apr. 3, 1984, as amended at 54 FR 16122, Apr. 21, 1989; 59 
FR 33447, June 29, 1994; 62 FR 40470, July 29, 1997]



752.225-70  Source, origin and nationality requirements.

    The following clause is required as prescribed in 725.704.

       Source, Origin and Nationality Requirements (February 1997)

    (a) Except as may be specifically approved by the Contracting 
Officer, all commodities (e.g., equipment, materials, vehicles, 
supplies) and services (including commodity transportation services) 
which will be financed under this contract with U.S. dollars shall be 
procured in accordance with the requirements in 22 CFR part 228, ``Rules 
on Source, Origin and Nationality for Commodities and Services Financed 
by USAID.'' The authorized source for procurement is Geographic Code 000 
unless otherwise specified in the schedule of this contract. Guidance on 
eligibility of specific goods or services may be obtained from the 
Contracting Officer.
    (b) Ineligible goods and services. The Contractor shall not procure 
any of the following goods or services under this contract:
    (1) Military equipment,
    (2) Surveillance equipment,
    (3) Commodities and services for support of police and other law 
enforcement activities,
    (4) Abortion equipment and services,
    (5) Luxury goods and gambling equipment, or
    (6) Weather modification equipment.
    (c) Restricted goods. The Contractor shall not procure any of the 
following goods or services without the prior written approval of the 
Contracting Officer:
    (1) Agricultural commodities,
    (2) Motor vehicles,
    (3) Pharmaceuticals and contraceptive items,
    (4) Pesticides,
    (5) Fertilizer,
    (6) Used equipment, or
    (7) U.S. government-owned excess property.
    If USAID determines that the Contractor has procured any of these 
specific restricted goods under this contract without the prior written 
authorization of the Contracting Officer, and has received payment for 
such purposes, the Contracting Officer may require the contractor to 
refund the entire amount of the purchase.
[62 FR 40470, July 29, 1997; 62 FR 45334, Aug. 27, 1997]



752.225-71  Local procurement.

    For use in any USAID contract involving performance overseas.

                    Local Procurement (February 1997)

    (a) Local procurement involves the use of appropriated funds to 
finance the procurement of goods and services supplied by local 
businesses, dealers, or producers, with payment normally being in the 
currency of the cooperating country.
    (b) All locally-financed procurements must be covered by source/
origin and nationality waivers as set forth in subpart F of 22 CFR part 
228 except as provided for in 22 CFR 228.40, Local procurement.
[62 FR 40470, July 29, 1997; 62 FR 45334, Aug. 27, 1997; 62 FR 47532, 
Sept. 9, 1997]



752.226-1  Determination of status as disadvantaged enterprise.

    As prescribed in 726.7006(a), insert the following provision:

          Disadvantaged Enterprise Representation (April 1991)

    The offeror/contractor shall submit a representation in the 
following form to the contracting officer:
    (a) Representation. The offeror represents that:
    (1) It {time}  is, {time}  is not a small disadvantaged business.
    (2) It {time}  is, {time}  is not an historically black college or 
university, as designated by the Secretary of Education pursuant to 34 
CFR 608.2.

[[Page 62]]

    (3) It {time}  is, {time}  is not a college or university having a 
student body in which more than 40 percent of the students are Hispanic 
American.
    (4) It {time}  is, {time}  is not a private voluntary organization 
which is controlled by individuals who are socially and economically 
disadvantaged.
    (b) Definitions. (1) Asian Pacific Americans, as used in this 
provision means United States citizens whose origins are in Japan, 
China, the Philippines, Vietnam, Korea, Samoa, Guam, the U.S. Trust 
Territory of the Pacific Islands (Republic of Palau), the Northern 
Mariana Islands, Laos, Kampuchea (Cambodia), Taiwan, Burma, Thailand, 
Malaysia, Indonesia, Singapore, Brunei, Republic of the Marshall 
Islands, or the Federated States of Micronesia.
    (2) Controlled by socially and economically disadvantaged 
individuals means management and daily business are controlled by one or 
more such individuals.
    (3) Native Americans, as used in this provision means American 
Indians, Eskimos, Aleuts, and native Hawaiians.
    (4) Owned by socially and economically disadvantaged individuals 
means at least 51 percent owned by one or more individuals who are both 
socially and economically disadvantaged, or a publicly owned business 
having at least 51 percent of its stock owned by one or more socially 
and economically disadvantaged individuals.
    (5) Small business concern, as used in this provision, means a U.S. 
concern, including its affiliates, that is independently owned and 
operated, not dominant in the field of operation in which it is bidding 
on Government contracts, and qualifies as a small business under the 
criteria and size standards in 13 CFR part 121.
    (6) Small disadvantaged business, as used in this provision, means a 
small business concern that:
    (i) Is at least 51 percent owned by one or more individuals who are 
both socially and economically disadvantaged, or a publicly owned 
business having at least 51 percent of its stock owned by one or more 
socially and economically disadvantaged individuals; and
    (ii) Has its management and daily business controlled by one or more 
such individuals.
    (7) Subcontinent Asian Americans, as used in this provision, means 
United States citizens whose origins are in India, Pakistan, Bangladesh, 
Sri Lanka, Bhutan, or Nepal.
    (c) Qualified groups. The offeror shall presume that socially and 
economically disadvantaged individuals include Black Americans, Hispanic 
Americans, Native Americans, Asian-Pacific Americans, Subcontinent Asian 
Americans, and women.

                           (End of Provision)

[56 FR 27209, June 13, 1991, as amended at 62 FR 40470, July 29, 1997]



752.226-2  Subcontracting with disadvantaged enterprises.

    As prescribed in 726.7007, insert the following clause:

       Subcontracting With Disadvantaged Enterprises (April 1997)

    Note: This clause does not apply to prime contractors that qualify 
as disadvantaged enterprises as described below.

    (a) Not less than ten (10) percent of the dollar value of this 
contract shall be subcontracted to disadvantaged enterprises as 
described in paragraph (b) of this clause.
    (b) Disadvantaged enterprises are U.S. organizations or individuals 
that are:
    (1) Business concerns (as defined in FAR 19.001) owned and 
controlled by socially and economically disadvantaged individuals;
    (2) Institutions designated by the Secretary of Education, pursuant 
to 34 CFR 608.2, as historically black colleges and universities:
    (3) Colleges and universities having a student body in which more 
than 40 percent of the students are Hispanic American; or
    (4) Private voluntary organizations which are controlled by 
individuals who are socially and economically disadvantaged.
    (c) Definitions. (1) Controlled by socially and economically 
disadvantaged individuals means management and daily business are 
controlled by one or more such individuals.
    (2) Owned by socially and economically disadvantaged individuals 
means at least 51 percent owned by one or more individuals who are both 
socially and economically disadvantaged, or a publicly owned business 
having at least 51 percent of its stock owned by one or more socially 
and economically disadvantaged individuals.
    (3) Socially and economically disadvantaged individuals has the same 
meaning as in FAR 19.001, except that the term also includes women.
    (d) Contractors should require representations from their 
subcontractors regarding their status as a disadvantaged enterprise. 
Contractors acting in good faith may rely on such representations by 
their subcontractors.

                             (End of clause)

[56 FR 27210, June 13, 1991, as amended at 62 FR 40470, July 29, 1997]

[[Page 63]]



752.226-3  Limitation on subcontracting.

    As prescribed in 726.7008, insert the following clause:

                Limitations on Subcontracting (June 1993)

    By submission of an offer and execution of a contract, the Offeror/
Contractor agrees that in performance of the contract, at least 51 
percent of the cost of contract performance incurred for personnel shall 
be expended for employees of the contractor or employees of other 
disadvantaged enterprises eligible under the terms of 706.302-71. For 
the purposes of this clause, independent contractors hired by the 
contractor shall be considered employees of the contractor.

                             (End of clause)

[58 FR 42255, Aug. 9, 1993, as amended at 62 FR 40470, July 29, 1997]



752.228-3  Worker's compensation insurance (Defense Base Act).

    As prescribed in 728.309, the following supplemental coverage is to 
be added to the clause specified in FAR 52.228-3 by the USAID 
contracting officer.

    (a) The Contractor agrees to procure Defense Base Act (DBA) 
insurance pursuant to the terms of the contract between USAID and 
USAID's DBA insurance carrier unless the Contractor has a DBA self 
insurance program approved by the Department of Labor or has an approved 
retrospective rating agreement for DBA.
    (b) If USAID or the contractor has secured a waiver of DBA coverage 
(see AIDAR 728.305-70(a)) for contractor's employees who are not 
citizens of, residents of, or hired in the United States, the contractor 
agrees to provide such employees with worker's compensation benefits as 
required by the laws of the country in which the employees are working, 
or by the laws of the employee's native country, whichever offers 
greater benefits.
    (c) The Contractor further agrees to insert in all subcontracts 
hereunder to which the DBA is applicable, a clause similar to this 
clause, including this sentence, imposing on all subcontractors a like 
requirement to provide overseas workmen's compensation insurance 
coverage and obtain DBA coverage under the USAID requirements contract.
[53 FR 50631, Dec. 16, 1988, as amended at 54 FR 16122, Apr. 21, 1989; 
56 FR 67226, Dec. 30, 1991]



752.228-7  Insurance--liability to third persons.

    As prescribed in 728.307-2(c), the following paragraph is to be 
added to the clause specified in FAR 52.228-7 as either paragraph (h) 
(if FAR 52.228-7 Alternate I is not used) or (i) (if FAR 52.228-7 
Alternate I is used):

    (  ) Insurance on private automobiles. If the Contractor or any of 
its employees or their dependents transport or cause to be transported 
(whether or not at contract expense) privately owned automobiles to the 
Cooperating Country, or they or any of them purchase an automobile 
within the Cooperating Country, the Contractor agrees to make certain 
that all such automobiles during such ownership within the Cooperating 
Country will be covered by a paid-up insurance policy issued by a 
reliable company providing the following minimum coverages or such other 
minimum coverages as may be set by the Mission Director, payable in 
United States dollars or its equivalent in the currency of the 
Cooperating Country: injury to persons, $10,000/$20,000; property 
damage, $5,000. The premium costs for such insurance shall not be a 
reimbursable cost under this contract. Copies of such insurance policies 
shall be preserved and made available as part of the Contractor's 
records which are required to be preserved and made available by the 
``Audit and Records--Negotiation'' clause of this contract.
[53 FR 50632, Dec. 16, 1988, as amended at 54 FR 16122, Apr. 21, 1989; 
62 FR 40470, July 29, 1997]



752.228-9  Cargo insurance.

    As prescribed in 728.313(a), the following preface is to be used 
preceding the text of the clause at FAR 52.228-9:

    Preface: To the extent that marine insurance is necessary or 
appropriate under this contract, the contractor shall ensure that U.S. 
marine insurance companies are offered a fair opportunity to bid for 
such insurance. This requirement shall be included in all subcontracts 
under this contract.
[53 FR 50632, Dec. 16, 1988]



752.228-70  Medical Evacuation (MEDEVAC) Services.

    As prescribed in 728.307-70, for use in all contracts requiring 
performance overseas:

[[Page 64]]

            Medical Evacuation (MEDEVAC) Services (Mar 1993)

    (a) Contractors agree to provide medevac service coverage to all 
U.S. citizen, U.S. resident alien, and Third Country National employees 
and their authorized dependents while overseas under an USAID financed 
direct contract. Coverage shall be obtained pursuant to the terms of the 
contract between USAID and USAID's medevac service provider unless 
exempted in accordance with paragraph (b) of this clause.
    (b) The following are exempted from the requirements in paragraph 
(a) of this clause:
    (i) Eligible employees and their dependents with a health program 
that includes sufficient medevac coverage as approved by the Contracting 
Officer.
    (ii) Eligible employees and their dependents located at Missions 
where the Mission Director makes a written determination to waive the 
requirement for such coverage based on findings that the quality of 
local medical services or other circumstances obviate the need for such 
coverage.
    (c) Contractors further agree to insert in all subcontracts 
hereunder to which the medevac coverage is applicable, a clause similar 
to this clause, including this sentence, imposing on all subcontractors 
a like requirement to provide medical evacuation services coverage and 
obtain medevac coverage in accordance with the contract between USAID 
and USAID's medevac service provider.
[59 FR 33447, June 29, 1994]



752.229-70  Federal, state and local taxes.

    For contracts involving performance overseas the clauses prescribed 
in FAR 29.401-3 or 29.401-4 may be modified to specify that the taxes 
referred to are United States taxes.



752.232-7  Payments under time-and-materials and labor-hour contracts.

    USAID uses the payment provision contained in FAR 52.232-7 in 
indefinite quantity contracts for professional services up to 120 days, 
as provided in USAIDAR 716.501(c). When this provision is used the 
following preamble will be included:

    For the purposes of this clause certain terms shall be interpreted 
as follows:
    The term contract(s) includes ``delivery order(s)''; ``hour(s)'', or 
``hourly'' may be calculated in terms of ``day(s)'' or ``daily (8 
hours)''; and ``materials'' includes ``other direct costs''.
[50 FR 11450, Apr. 3, 1986]



752.232-70  Letter of credit advance payment.

    As required by 732.406-73 insert the following clause in contracts 
being paid by Letter of Credit.

              Letter of Credit Advance Payment (Oct. 1989)

    (a) Payment under this contract shall be by means of a Letter of 
Credit (LOC) in accordance with the terms and conditions of the LOC and 
any instructions issued by the USAID Office of Financial Management, 
Cash Management and Payment Division (FM/CMP).
    (b) As long as the LOC is in effect, the terms and conditions of the 
LOC and any instructions issued by FM/CMP constitute the payment 
conditions of this contract, superseding and taking precedence over any 
other clause of this contract concerning payment.
    (c) If the LOC is revoked, payment may be made on a cost-
reimbursement basis, in accordance with the other clauses of this 
contract concerning payment.
    (d) Revocation of the LOC is at the discretion of FM/CMP after 
consultation with the contracting officer. Notification to the 
contractor of revocation must be in writing and must specify the reasons 
for such action. The contractor may appeal any such revocation to the 
contracting officer, in accordance with the Disputes clause of this 
contract. Pending final decision, payments under the contact will be in 
accordance with paragraph (c) of this clause.
[49 FR 13259, Apr. 3, 1984, as amended at 49 FR 33668, Aug. 24, 1984; 54 
FR 46391, Nov. 3, 1989; 56 FR 67226, Dec. 30, 1991; 59 FR 33447, June 
29, 1994]



752.245-70  Government property--USAID reporting requirements.

    In response to a GAO audit recommendation, USAID contracts, except 
for those for commercial items, must contain the following preface and 
reporting requirement as additions to the appropriate Government 
Property clause prescribed by FAR 45.106.

    Preface: to be inserted preceding the text of the FAR clause.
    The term Government furnished property wherever it may appear in the 
following clause, shall mean (1) non-expendable personal property owned 
by or leased to the U.S. Government and furnished to the contractor and 
(2) personal property furnished either prior to or during the 
performance of this contract by any U.S. Government accountable officer 
to the contractor for use in connection with performance of this 
contract and identified by such officer as accountable.

[[Page 65]]

The term government property, wherever it may appear in the following 
clause, shall mean government-furnished property and non-expendable 
personal property title to which vests in the U.S. Government under this 
contract. Non-expendable property, for purposes of this contract, is 
defined as property which is complete in itself, does not lose its 
identity or become a component part of another article when put into 
use; is durable, with an expected service life of two years or more; and 
which has a unit cost of more than $500.
    Reporting Requirement: to be inserted following the text of the FAR 
clause.
    Reporting Requirements: The contractor will submit an annual report 
on all non-expendable property in a form and manner acceptable to USAID 
substantially as follows:

      Annual Report of Government Property in Contractor's Custody      
        [(Name of contractor) as of (end of contract year), 19xx]       
------------------------------------------------------------------------
                                              Furniture and             
                                              furnishings--      Other  
              Motor vehicles               ------------------ nonexpend-
                                                     Living      able   
                                            Office  quarters   property 
------------------------------------------------------------------------
A. Value of property as of last report....  ......  ........  ..........
B. Transactions during this reporting                                   
 period...................................  ......  ........  ..........
1. Acquisitions (add):                                                  
  a. Purchased by contractor \1\..........  ......  ........  ..........
  b. Transferred from USAID \2\...........  ......  ........  ..........
  c. Transferred from others, without                                   
   reimbursement \3\......................  ......  ........  ..........
2. Disposals (deduct):                                                  
  a. Returned to USAID....................  ......  ........  ..........
  b. Transferred to USAID--contractor                                   
   purchased..............................  ......  ........  ..........
  c. Transferred to other Government                                    
   agencies \3\...........................  ......  ........  ..........
  d. Other disposals \3\..................  ......  ........  ..........
C. Value of property as of reporting date.  ......  ........  ..........
D. Estimated average age of contractor                                  
 held property............................  ......  ........  ..........
------------------------------------------------------------------------
                                             Years    Years     Years   
------------------------------------------------------------------------
\1\ Property which is complete in itself, does not lose its identity or 
  become a component part of another article when put into use; is      
  durable, with an expected service life of two years or more; and which
  has a unit cost of more than $500.                                    
\2\ Government furnished property listed in this Contract as            
  nonexpendable.                                                        
\3\ Explain if transactions were not processed through or otherwise     
  authorized by USAID.                                                  

                    Property Inventory Verifications

    I attest that (1) physical inventories of Government property are 
taken not less frequently than annually; (2) the accountability records 
maintained for Government property in our possession are in agreement 
with such inventories; and (3) the total of the detailed accountability 
records maintained agrees with the property value shown opposite line C 
above, and the estimated average age of each category of property is as 
cited opposite line D above.
 _______________________________________________________________________

                          Authorized Signature

[49 FR 13259, Apr. 3, 1984, as amended at 62 FR 40470, July 29, 1997]



752.245-71  Title to and care of property.

    The following clause shall be included in all non-commercial 
contracts when the contractor will acquire property under the contract 
for use overseas and the property will be titled to the Cooperating 
Country.

                Title to and Care of Property (Apr. 1984)

    (a) Title to all non-expendable property purchased with contract 
funds under this contract and used in the Cooperating Country, shall at 
all times be in the name of the Cooperating Government, or such public 
or private agency as the Cooperating Government may designate, unless 
title to specified types or classes of non-expendable property is 
reserved to USAID under provisions set forth in the schedule of this 
contract; but all such property shall be under the custody and control 
of Contractor until the owner of title directs otherwise, or completion 
of work under this contract or its termination, at which time custody 
and control shall be turned over to the owner of title or disposed of in 
accordance with its instructions. All performance guaranties and 
warranties obtained from suppliers shall be taken in the name of the 
title owner. (Non-expendable property is property which is complete in 
itself, does not lose its identity or become a component part of another 
article when put into use; is durable, with an expected service life of 
two years or more; and which has a unit cost of $500 of more.)
    (b) Contractor shall prepare and establish a program, to be approved 
by the Mission, for the receipt, use, maintenance, protection, custody, 
and care of non-expendable property for which it has custodial 
responsibility, including the establishment of reasonable controls to 
enforce such program.
    (c)(1) For non-expendable property to which title is reserved to the 
U.S. Government under provisions set forth in the schedule of this 
contract, Contractor shall submit an annual report on all non-expendable 
property under its custody as required in the clause of this contract 
entitled ``Government Property''.
    (2) For non-expendable property titled to the Cooperating 
Government, the Contractor shall, within 90 days after completion of 
this contract, or at such other date as may be

[[Page 66]]

fixed by the Contracting Officer, submit an inventory schedule covering 
all items of non-expendable property under its custody, which have not 
been consumed in the performance of this contract. The Contractor shall 
also indicate what disposition has been made of such property.I56Subpart 
752.70--Texts of USAID Contract Clauses
[49 FR 13259, Apr. 3, 1984, as amended at 62 FR 40470, July 29, 1997]



             Subpart 752.70--Texts of USAID Contract Clauses



752.7000  Scope of subpart.

    Subpart 752.70 contains the text of USAID-specific contract clauses 
for which there is no FAR equivalent. The clauses in this subpart do not 
apply to contracts for personal services. For personal service contract 
clauses see AIDAR Appendix D--Direct USAID Contracts with U.S. Citizens 
or U.S. Residents for Personal Services Abroad and AIDAR Appendix J--
Direct USAID Contracts with Cooperating Country Nationals and with Third 
Country Nationals for Personal Services Abroad.
[49 FR 13259, Apr. 3, 1984, as amended at 57 FR 5237, Feb. 13, 1992]



752.7001  Biographical data.

    The following clause is to be included in all USAID cost 
reimbursement contracts.

                      Biographical Data (July 1997)

    The Contractor agrees to furnish to the Contracting Officer on USAID 
Form 1420-17, ``Contractor Employee Biographical Data Sheet'', 
biographical information on the following individuals to be employed in 
the performance of the contract: (1) All individuals to be sent outside 
the United States, or (2) any employees designated as ``key personnel''. 
Biographical data in the form usually maintained by the Contractor on 
the other individuals employed under the contract shall be available for 
review by USAID at the Contractor's headquarters. A supply of USAID Form 
1420-17 will be provided with this contract. The Contractor may 
reproduce additional copies as necessary.
[62 FR 40470, July 29, 1997; 62 FR 45334, Aug. 27, 1997; 62 FR 47532, 
Sept. 9, 1997]



752.7002  Travel and transportation.

    For use in cost reimbursement contracts performed in whole or in 
part overseas.

                  Travel and Transportation (Jan. 1990)

    (a) General. The Contractor will be reimbursed for reasonable, 
allocable and allowable travel and transportation expenses incurred 
under and for the performance of this contract. Determination of 
reasonableness, allocability and allowability will be made by the 
Contracting Officer based on the applicable cost principles, the 
Contractor's established policies and procedures, USAID's established 
policies and procedures for USAID direct-hire employees, and the 
particular needs of the project being implemented by this contract. The 
following paragraphs provide specific guidance and limitations on 
particular items of cost.
    (b) International travel. For travel to and from post of assignment 
the Contractor shall be reimbursed for travel costs and travel 
allowances of travelers from place of residence in the United States (or 
other location provided that the cost of such travel does not exceed the 
cost of the travel from the employee's residence in the United States) 
to the post of duty in the Cooperating Country and return to place of 
residence in the United States (or other location provided that the cost 
of such travel does not exceed the cost of travel from the post of duty 
in the Cooperating Country to the employee's residence) upon completion 
of services by the individual. Reimbursement for travel will be in 
accordance with the applicable cost principles and the provisions of 
this contract, and will be limited to the cost of travel by the most 
direct and expeditious route. If a regular employee does not complete 
one full year at post of duty (except for reasons beyond his/her 
control), the costs of going to and from the post of duty for that 
employee and his/her dependents are not reimbursable hereunder. If the 
employee serves more than one year but less than the required service in 
the Cooperating Country (except for reasons beyond his/her control) the 
costs of going to the post of duty are reimbursable hereunder but the 
costs of going from post of duty to the employee's permanent, legal 
place of residence at the time he or she was employed for work under 
this contract or other location as approved by the Contracting Officer 
are not reimbursable under this contract for the employee and his/her 
dependents. When travel is by economy class accommodations, the 
Contractor will be reimbursed for the cost of transporting up to 22 
pounds of accompanied personal baggage per traveler in addition to that 
regularly allowed with the economy ticket provided that the total number 
of pounds of baggage does not exceed that regularly allowed for first 
class travelers. Travel allowances for travelers shall not be in excess 
of the rates authorized in the Standardized Regulations (Government 
Civilians, Foreign Areas)--hereinafter referred to as the Standardized 
Regulations--as from

[[Page 67]]

time to time amended, for not more than the travel time required by 
scheduled commercial air carrier using the most expeditious route. One 
stopover en route for a period of not to exceed 24 hours is allowable 
when the traveler uses economy class accommodations for a trip of 14 
hours or more of scheduled duration. Such stopover shall not be 
authorized when travel is by indirect route or is delayed for the 
convenience of the traveler. Per diem during such stopover shall be paid 
in accordance with the established practice of the Contractor but not to 
exceed the amounts stated in the Standardized Regulations.
    (c) Local travel. Reimbursement for local travel in connection with 
duties directly referable to the contract shall not be in excess of the 
rates established by the Mission Director for the travel costs of 
travelers in the Cooperating Country. In the absence of such established 
rates the Contractor shall be reimbursed for actual travel costs of 
travelers in the Cooperating Country, if not provided by the Cooperating 
Government or the Mission, including travel allowances at rates not in 
excess of those prescribed by the Standardized Regulations.
    (d) Travel for consultation. The Contractor shall be reimbursed for 
the round trip of the Contractor's Chief of Party in the Cooperating 
Country or other designated Contractor employee or consultant in the 
Cooperating Country performing services required under this Contract, 
for travel from the Cooperating Country to the Contractor's office in 
the United States or to USAID/Washington for consultation and return on 
occasions deemed necessary by the Contractor and approved in advance, in 
writing, by the Contracting Officer or the Mission Director.
    (e) Special international travel and third country travel. For 
special travel which advances the purpose of the contract, which is not 
otherwise provided by the Cooperating Government, and with the prior 
written approval of the Contracting Officer or the Mission Director, the 
Contractor shall be reimbursed for (i) the travel cost of travelers 
other than between the United States and the Cooperating Country and for 
local travel within other countries and (ii) travel allowance for 
travelers while in travel status and while performing services hereunder 
in such other countries at rates not in excess of those prescribed by 
the Standardized Regulations.
    (f) Indirect travel for personal convenience. When travel is 
performed by an indirect route for the personal convenience of the 
traveler, the allowable costs of such travel will be computed on the 
basis of the cost of allowable air fare via the direct usually traveled 
route. If such costs include fares for air or ocean travel by foreign 
flag carriers, approval for indirect travel by such foreign flag 
carriers must be obtained from the Contracting Officer or the Mission 
Director before such travel is undertaken, otherwise only that portion 
of travel accomplished by United States-flag carriers will be 
reimbursable within the above limitation of allowable costs.
    (g) Limitation on travel by dependents. Travel costs and allowances 
will be allowed only for dependents of regular employees and such costs 
shall be reimbursed for travel from place of abode to assigned station 
in the Cooperating Country and return, only if dependent remains in the 
country for at least 9 months or one-half of the required tour of duty 
of the regular employee responsible for such dependent, whichever is 
greater. If the dependent is eligible for educational travel pursuant to 
the ``Differential and Allowances'' clause of this contract, time spent 
away from post resulting from educational travel will be counted as time 
at post.
    (h) Delays en route. The Contractor may grant to travelers under 
this contract reasonable delays en route while in travel status when 
such delays are caused by events beyond the control of such traveler or 
Contractor. It is understood that if delay is caused by physical 
incapacitation, personnel shall be eligible for such sick leave as 
provided under the ``Leave and Holidays'' clause of this contract.
    (i) Travel by privately owned automobile. The Contractor shall be 
reimbursed for the cost of travel performed by a regular employee in 
his/her privately owned automobile at a rate not to exceed that 
authorized in the Federal Travel Regulations plus authorized per diem 
for the employee and for each of the authorized dependents traveling in 
the automobile, if the automobile is being driven to or from the 
Cooperating Country as authorized under the contract, provided that the 
total cost of the mileage and the per diem paid to all authorized 
travelers shall not exceed the total constructive cost of fare and 
normal per diem by all authorized travelers by surface common carrier or 
authorized air fare, whichever is less.
    (j) Emergency and irregular travel and transportation. Emergency 
transportation costs and travel allowances while en route, as provided 
in this section will also be reimbursed not to exceed amounts authorized 
by the Foreign Service Travel Regulations for USAID-direct hire 
employees in like circumstances under the following conditions:
    (1) The costs of going from post of duty in the Cooperating Country 
to the employee's permanent, legal place of residence at the time he or 
she was employed for work under this contract or other location for 
Contractor employees and dependents and returning to the post of duty, 
when the Contractor's Chief of Party, with the concurrence of the 
Contracting Officer or Mission Director makes a written determination 
that such travel is necessary for one of the reasons

[[Page 68]]

specified in subparagraphs (j)(1) (i) and (ii) of this section. A copy 
of the written determination shall be furnished to the Contracting 
Officer.
    (i) Need for medical care beyond that available within the area to 
which the employee is assigned, or serious effect on physical or mental 
health if residence is continued at assigned post of duty, subject in 
either case, to the limitations stated in the clause of this contract 
entitled ``Personnel--Physical Fitness of Employee and Dependents.'' The 
Mission Director may authorize a medical attendant to accompany the 
employee at contract expense if, based on medical opinion, such an 
attendant is necessary.
    (ii) Death, or serious illness or injury of a member of the 
immediate family of the employee or the immediate family of the 
employee's spouse.
    (2) When, for any reason, the Mission Director determines it is 
necessary to evacuate the Contractor's entire team (employees and 
dependents) or Contractor dependents only, the Contractor will be 
reimbursed for travel and transportation expenses and travel allowance 
while en route, for the cost of the individuals going from post of duty 
in the Cooperating Country to the employee's permanent, legal place of 
residence at the time he or she was employed for work under this 
contract or other approved location. The return of such employees and 
dependents may also be authorized by the Mission Director when, in his/
her discretion, he/she determines it is prudent to do so.
    (3) The Mission Director may also authorize emergency or irregular 
travel and transportation in other situations, when in his/her opinion, 
the circumstances warrant such action. The authorization shall include 
the kind of leave to be used and appropriate restrictions as to time 
away from post, transportation of personal and/or household effects, 
etc. Requests for such emergency travel shall be submitted through the 
Contractor's Chief of Party.
    (k) Home leave travel. To the extent that home leave has been 
authorized as provided in the ``Leave and Holidays'' clause of this 
contract, the cost of travel for home leave is reimbursable for travel 
costs and travel allowances of travelers from the post of duty in the 
Cooperating Country to place of residence in the United States (or other 
location provided that the cost of such travel does not exceed the cost 
of travel to the employee's residence in the United States) and return 
to the post of duty in the Cooperating Country. Reimbursement for travel 
will be in accordance with the applicable cost principles and the 
provisions of this contract, and will be limited to the cost of travel 
by the most direct and expeditious route. When travel is by economy 
class accommodations, the Contractor will be reimbursed for the cost of 
transporting up to 22 pounds of accompanied personal baggage per 
traveler in addition to that regularly allowed with the economy ticket 
provided that the total number of pounds of baggage does not exceed that 
regularly allowed for first class travelers. Travel allowances for 
travelers shall not be in excess of the rates authorized in the 
Standardized Regulations as from time to time amended, for not more than 
the travel time required by scheduled commercial air carrier using the 
most expeditious route. One stopover en route for a period of not to 
exceed 24 hours is allowable when the traveler uses economy class 
accommodations for a trip of 14 hours or more of scheduled duration. 
Such stopover shall not be authorized when travel is by indirect route 
or is delayed for the convenience of the traveler. Per diem during such 
stopover shall be paid in accordance with the established practice of 
the Contractor but not to exceed the amounts stated in the Standardized 
Regulations.
    (l) Rest and recuperation travel. The Contractor shall be reimbursed 
for the cost of travel performed by regular employees and dependents for 
purposes of rest and recuperation provided that such reimbursement does 
not exceed that authorized for USAID direct hire employees, and provided 
further that no reimbursement will be made unless approval is given by 
the Contractor's Chief of party.
    (m) Transportation of motor vehicles, personal effects and household 
goods. (1) Transportation, including packing and crating costs, will be 
paid for shipping from the point of origin in the United States (or 
other location as approved by the Contracting Officer) to post of duty 
in the Cooperating Country and return to point of origin in the United 
States (or other location as approved by the Contracting Officer) of one 
privately-owned vehicle for each regular employee, personal effects of 
travelers and household goods of each regular employee not to exceed the 
limitations in effect for such shipments for USAID direct hire employees 
in accordance with the Foreign Service Travel Regulations as in effect 
when shipment is made.
    (2) If a regular employee does not complete one full year at post of 
duty (except for reasons beyond his/her control), the costs for 
transportation of vehicles, effects and goods to and from the post of 
duty are not reimbursable hereunder. If the employee serves more than 
one year but less than the required service in the Cooperating Country 
(except for reasons beyond his/her control) the costs for transportation 
of vehicles, effects and goods to the post of duty are reimbursable 
hereunder but the costs for transportation of vehicles, effects and 
goods from post of duty to the employee's permanent, legal place of 
residence at the time he or she was employed for work under this 
contract or other location as approved by the Contracting Officer are 
not reimbursable under this contract.

[[Page 69]]

    (3) The cost of transporting motor vehicles and household goods 
shall not exceed the cost of packing, crating and transportation by 
surface. In the event that the carrier does not require boxing or 
crating of motor vehicles for shipment to the Cooperating Country, the 
cost of boxing or crating is not reimbursable. The transportation of a 
privately-owned motor vehicle for a regular employee may be authorized 
by the Contractor as replacement of the last such motor vehicle shipped 
under this contract for the employee when the Mission Director or his/
her designee determines in advance and so notifies the Contractor in 
writing that the replacement is necessary for reasons not due to the 
negligence or malfeasance of the regular employee. The determination 
shall be made under the same rules and regulations that apply to Mission 
employees.
    (n) Unaccompanied baggage. Unaccompanied baggage is considered to be 
those personal belongings needed by the traveler immediately upon 
arrival at destination. To permit the arrival of effects to coincide 
with the arrival of regular employees and dependents, consideration 
should be given to advance shipments of unaccompanied baggage. The 
Contractor will be reimbursed for costs of shipment of unaccompanied 
baggage (in addition to the weight allowance for household effects) not 
to exceed the limitations in effect for USAID direct hire employees in 
accordance with the Foreign Service Travel Regulations as in effect when 
shipment is made.
    This unaccompanied baggage may be shipped as air freight by the most 
direct route between authorized points of origin and destination 
regardless of the modes of travel used. This provision is applicable to 
home leave travel and to short-term employees when these are authorized 
by the terms of this contract.
    (o) Storage of household effects. The cost of storage charges 
(including packing, crating, and drayage costs) in the U.S. of household 
goods of regular employees will be permitted in lieu of transportation 
of all or any part of such goods to the Cooperating Country under 
paragraph (m) above provided that the total amount of effects shipped to 
the Cooperating Country or stored in the U.S. shall not exceed the 
amount authorized for USAID direct hire employees under the Uniform 
Foreign Service Travel Regulations.
    (p) International ocean transportation. (1) Flag eligibility 
requirements for ocean carriage are covered by the ``Source and 
Nationality Requirements'' clause of this contract.
    (i) Transportation of things. Where U.S. flag vessels are not 
available, or their use would result in a significant delay, the 
Contractor may obtain a release from this requirement from the 
Transportation Division, Office of Procurement, U.S. Agency for 
International Development, Washington, DC. 20523-1419, or the Mission 
Director, as appropriate, giving the basis for the request.
    (ii) Transportation of persons. Where U.S. flag vessels are not 
available, or their use would result in a significant delay, the 
Contractor may obtain a release from this requirement from the 
Contracting Officer or the Mission Director, as appropriate.
    (2) Transportation of foreign-made vehicles. Reimbursement of the 
costs of transporting a foreign-made motor vehicle will be made in 
accordance with the provisions of the Foreign Service Travel 
Regulations.
    (3) Reduced rates on U.S. flag carriers. Reduced rates on United 
States flag carriers are in effect for shipments of household goods and 
personal effects of USAID contract personnel. These reduced rates are 
available provided the shipper states on the bill of lading that the 
cargo is ``Personal property-not for resale-payment of freight charges 
is at U.S. Government (USAID) expense and any special or diplomatic 
discounts accorded this type cargo are applicable.'' The Contractor will 
not be reimbursed for shipments of household goods or personal effects 
in an amount in excess of the reduced rates available in accordance with 
the foregoing.

                             (End of clause)

[55 FR 6803, Feb. 27, 1990, as amended at 56 FR 2699, Jan. 24, 1991]



752.7003  Documentation for payment.

    The following clause is required in all USAID-direct cost-
reimbursement contracts:

                  Documentation for Payment (Apr. 1984)

    (a) Claims for reimbursement under this contract shall be submitted 
to the Paying Office indicated on the cover page of this contract. The 
authorized Certifying Officer of the Paying Office is the designated 
representative of the Contracting Officer, authorized to approve 
vouchers under this contract. The Contractor shall submit a Voucher Form 
SF-1034 (original) and SF-1034(a) in three copies. Each voucher shall be 
identified by the appropriate USAID contract number, properly executed, 
in the amount of dollar expenditures made during the period covered. The 
voucher forms shall be supported by:
    (1) Original and three copies of a certified fiscal report rendered 
by the Contractor in a form and manner satisfactory to USAID 
substantially as follows:

[[Page 70]]



                           TOTAL EXPENDITURES                           
------------------------------------------------------------------------
                                                                  This  
                                              Budget             period 
                  Category                    amount  To date  (indicate
                                                                 dates) 
------------------------------------------------------------------------
Salaries and wages:                                                     
  Home office...............................    $XXX     $XXX      $XXX 
  Field office..............................     XXX      XXX       XXX 
Indirect costs:                                                         
  Home office...............................     XXX      XXX       XXX 
  Field office..............................     XXX      XXX       XXX 
Consultant fees.............................     XXX      XXX       XXX 
Allowances..................................     XXX      XXX       XXX 
Travel and transportation...................     XXX      XXX       XXX 
Expendable equipment and materials..........     XXX      XXX       XXX 
Non-expendable property.....................     XXX      XXX       XXX 
Participant costs...........................     XXX      XXX       XXX 
Other direct costs..........................     XXX      XXX       XXX 
                                             ---------------------------
    Grand total.............................    $XXX     $XXX      $XXX 
------------------------------------------------------------------------

    (2) The fiscal report shall include a certification; signed by an 
authorized representative of the Contractor, as follows:
    The undersigned hereby certifies that (i) the fiscal report and any 
attachments have been prepared from the books and records of the 
Contractor in accordance with the terms of this contract, and to the 
best of my knowledge and belief, that they are correct, that the sum 
claimed under this Contract is proper and due, that all the costs of 
contract performance (except as herewith reported in writing) have been 
paid or will be paid currently by the Contractor when due in the 
ordinary course of business, that the work reflected by the costs above 
has been performed, that the quantities and amounts involved are 
consistent with the requirements of this Contract, that all required 
Contracting Officer approvals have been obtained, and (ii) appropriate 
refund to USAID will be made promptly upon request in the event of 
disallowance of costs not reimbursable under the terms of this Contract.

 By:____________________________________________________________________
 Title:_________________________________________________________________
 Date:__________________________________________________________________

    (3) Unless otherwise provided in this contract, the Contractor shall 
submit a vendor's invoice detailing the quantity, description, and price 
for each individual item purchased, as follows:
    (i) Expendable equipment, supplies, or commodities--for transactions 
totaling more than $2,500.
    (ii) Non-expendable property--for every purchase. Non-expendable 
property is property which is complete in itself, does not lose its 
identity or become a component part of another article when put into 
use; is durable, with an expected service life of two years or more; and 
which has be a unit cost of more than $500.
    (iii) The bill of lading or airway bill as evidence of shipment by 
U.S.-flag carrier.
    (b) Local currency payment. The Contractor is fully responsible for 
the proper expenditure and control of local currency, if any, provided 
under this contract. Local currency will be provided to the Contractor 
in accordance with written instructions provided by the Mission 
Director. The written instructions will also include accounting, 
vouchering, and reporting procedures. A copy of the instructions shall 
be provided to the Contractor's Chief of Party and to the Contracting 
Officer. The costs of bonding personnel responsible for local currency 
are reimbursable under this contract.
    (c) Upon compliance by the Contractor with all the provisions of 
this contract, acceptance by the Government of the work and final 
report, and a satisfactory accounting by the Contractor of all 
Government-owned property for which the Contractor had custodial 
responsiblity, the Government shall promptly pay to the Contractor any 
moneys (dollars or local currency) due under the completion voucher. The 
Government will make suitable reduction for any disallowance or 
indebtedness by the Contractor by applying the proceeds of the voucher 
first to such deductions and next to any unliquidated balance of advance 
remaining under this contract.
    (d) The Contractor agrees that all approvals of the Mission Director 
and the Contracting Officer which are required by the provisions of this 
contract shall be preserved and made available as part of the 
Contractor's records which are required to be presented and made 
available by the clauses of this contract entitled ``Examination of 
Records by Comptroller General'' and ``Audit''.
[53 FR 6829, Mar. 3, 1988]



752.7004  Emergency locator information.

    The following clause is to be included in all contracts requiring 
travel overseas.

                Emergency Locator Information (July 1997)

    The Contractor agrees to provide the following information to the 
Mission Administrative Officer on or before the arrival in the host 
country of every contract employee or dependent:
    (1) The individual's full name, home address, and telephone number.
    (2) The name and number of the contract, and whether the individual 
is an employee or dependent.
    (3) The contractor's name, home office address, and telephone 
number, including any after-hours emergency number(s), and the name of 
the contractor's home office staff

[[Page 71]]

member having administrative responsibility for the contract.
    (4) The name, address, and telephone number(s) of each individual's 
next of kin.
    (5) Any special instructions pertaining to emergency situations such 
as power of attorney designees or alternate contact persons.
[62 FR 40470, July 29, 1997; 62 FR 45334, Aug. 27, 1997]



752.7005  [Reserved]



752.7006  Notices.

    The following clause shall be used in all USAID contracts.

                           Notices (Apr. 1984)

    Any notice given by any of the parties hereunder shall be sufficient 
only if in writing and delivered in person or sent by telegraph, cable, 
or registered or regular mail as follows:
    To USAID: Administrator, U.S. Agency for International Development, 
Washington, DC 20523-0061. Attention: Contracting Officer (the name of 
the cognizant Contracting Officer with a copy to the appropriate Mission 
Director).
    To Contractor: At Contractor's address shown on the cover page of 
this contract, or to such other address as either of such parties shall 
designate by notice given as herein required. Notices hereunder shall be 
effective when delivered in accordance with this clause or on the 
effective date of the notice, whichever is later.
[49 FR 13259, Apr. 3, 1984, as amended at 56 FR 2699, Jan. 24, 1991; 61 
FR 39095, July 26, 1996]



752.7007  Personnel compensation.

    The following clause shall be used in all USAID cost-reimbursement 
contracts.

                   Personnel Compensation (July 1996)

    (a) Direct compensation of the Contractor's personnel will be in 
accordance with the Contractor's established policies, procedures, and 
practices, and the cost principles applicable to this contract.
    (b) Compensation (i.e., the employee's base annual salary plus 
overseas recruitment incentive, if any) which exceeds the maximum 
payable annual or daily rate for an Executive Service level ES-6, as 
published in the Federal Register, will be reimbursed only with the 
approval of the Contracting Officer, as prescribed in 731.205-6(d) or 
731.371(b), as applicable.
[49 FR 13259, Apr. 3, 1984, as amended at 49 FR 33669, Aug. 24, 1984; 61 
FR 39095, July 26, 1996; 62 FR 40470, July 29, 1997]



752.7008  Use of Government facilities or personnel.

    The following clause is for use in all USAID non-commercial 
contracts.

          Use of Government Facilities or Personnel (Apr. 1984)

    (a) The Contractor and any employee or consultant of the Contractor 
is prohibited from using U.S. Government facilities (such as office 
space or equipment) or U.S. Government clerical or technical personnel 
in the performance of the services specified in the contract, unless the 
use of Government facilities or personnel is specifically authorized in 
the contract, or is authorized in advance, in writing, by the 
Contracting Officer.
    (b) If at any time it is determined that the Contractor, or any of 
its employees or consultants have used U.S. Government facilities or 
personnel without authorization either in the contract itself, or in 
advance, in writing, by the Contracting Officer, then the amount payable 
under the contract shall be reduced by an amount equal to the value of 
the U.S. Government facilities or personnel used by the Contractor, as 
determined by the Contracting Officer.
    (c) If the parties fail to agree on an adjustment made pursuant to 
this clause, it shall be considered a dispute, and shall be dealt with 
under the terms of the clause of this contract entitled ``Disputes''.
[49 FR 13259, Apr. 3, 1984, as amended at 62 FR 40470, July 29, 1997



752.7009  Marking.

    The following clause is for use in all USAID contracts performed in 
whole or in part overseas.

                           Marking (Jan. 1993)

    (a) It is USAID policy that USAID-financed commodities and shipping 
containers, and project construction sites and other project locations 
be suitably marked with the USAID emblem. Shipping containers are also 
to be marked with the last five digits of the USAID financing document 
number. As a general rule, marking is not required for raw materials 
shipped in bulk (such as coal, grain, etc.), or for semifinished 
products which are not packaged.
    (b) Specific guidance on marking requirements should be obtained 
prior to procurement of commodities to be shipped, and as early as 
possible for project construction sites and other project locations. 
This guidance will be provided through the cognizant technical office 
indicated on the cover page of this contract, or by the Mission Director 
in the Cooperating Country to which commodities are being shipped, or in 
which the project site is located.

[[Page 72]]

    (c) Authority to waive marking requirements is vested with the 
Regional Assistant Administrators, and with Mission Directors.
    (d) A copy of any specific marking instructions or waivers from 
marking requirements is to be sent to the Contracting Officer; the 
original should be retained by the Contractor.
[49 FR 13259, Apr. 3, 1984, as amended at 58 FR 8703, Feb. 17, 1993]



752.7010  Conversion of U.S. dollars to local currency.

    For use in all USAID non-commercial contracts involving performance 
overseas.

        Conversion of U.S. Dollars to Local Currency (Apr. 1984)

    Upon arrival in the Cooperation Country, and from time to time as 
appropriate, the Contractor's Chief of Party shall consult with the 
Mission Director who shall provide, in writing, the procedure the 
Contractor and its employees shall follow in the conversion of United 
States dollars to local currency. This may include, but is not limited 
to, the conversion of said currency through the cognizant U.S. 
Disbursing Officer or Mission Controller, as appropriate.
[49 FR 13259, Apr. 3, 1984, as amended at 62 FR 40470, July 29, 1997]



752.7011  Orientation and language training.

    For use in all USAID cost-reimbursement contracts involving 
performance overseas.

              Orientation and Language Training (Apr. 1984)

    (a) Regular employees shall receive a maximum of 2 weeks USAID 
sponsored orientation before travel overseas. The dates of orientation 
shall be selected by the Contractor from the orientation schedule 
provided by USAID.
    (b) Participation in USAID sponsored orientation in no way relieves 
the Contractor of its responsibility for assuring that all employees, 
regular and short-term, are properly oriented. As an addition to or 
substitution for USAID's sponsored orientation for regular employees, 
the following types of orientation may be authorized taking into 
consideration specific job requirements, the employee's prior overseas 
experience, or unusual circumstances.
    (1) Modified orientation.
    (2) Language training, particularly when significant for operating 
capabilities.
    (3) Orientation and language training for regular employee's 
dependents.
    (4) Contractor-sponsored orientation.
    (5) Orientation in all matters related to the administrative, 
logistical, and technical aspects of the employee's movement to, and 
tour of duty in, the Cooperating Country.
    (c) Authorization for an additional or alternate orientation 
program, if any, shall be either set forth in the schedule or provided 
in writing by the Contracting Officer.
    (d) Travel expenses not to exceed one round trip from regular 
employee's residence to place of orientation and return will be 
reimbursed, pursuant to the cost principles applicable to this contract. 
Allowable salary costs during the period of orientation are also 
reimbursable.



752.7012  Protection of the individual as a research subject.

    This clause is for use in any USAID contract which involves research 
using human subjects.

    Protection of the Individual as a Research Subject (August 1995)

    (a) Safeguarding the rights and welfare of human subjects in 
research conducted under a USAID contract is the responsibility of the 
contractor. USAID has adopted the Common Federal Policy for the 
Protection of Human Subjects. USAID's Policy is found in Part 225 of 
Title 22 of the Code of Federal Regulations (the ``Policy''). Additional 
interpretation, procedures, and implementation guidance of the Policy 
are found in USAID General Notice entitled ``Procedures for the 
Protection of Human Subjects in Research Supported by USAID'', issued 
April 19, 1995, as from time to time amended (a copy of which is 
attached to this contract). USAID's Cognizant Human Subjects Officer 
(CHSO) and USAID/W has oversight, guidance, and interpretation 
responsibility for the Policy.
    (b) Contractors must comply with the Policy when humans are the 
subject of research, as defined in 22 CFR 225.102(d), performed as part 
of the contract, and contractors must provide ``assurance'', as required 
by 22 CFR 225.103, that they follow and abide by the procedures in the 
Policy. See also Section 5 of the April 19, 1995, USAID General Notice 
which sets forth activities to which the Policy is applicable. The 
existence of a bona fide, applicable assurance approved by the 
Department of Health and Human Services (HHS) such as the ``multiple 
project assurance'' (MPA) will satisfy this requirement. Alternatively, 
contractors can provide an acceptable written assurance to USAID as 
described in 22 CFR 225.103. Such assurances must be determined by the 
CHSO to be acceptable prior to any applicable research being initiated 
or conducted under the contract. In some limited instances outside the 
U.S., alternative systems for the protection of human subjects may be 
used provided they are deemed ``at least equivalent'' to those

[[Page 73]]

outlined in Part 225 (see 22 CFR 225.101(h)). Criteria and procedures 
for making this determination are described in the General Notice cited 
in the preceding paragraph.
    (c) Since the welfare of the research subject is a matter of concern 
to USAID as well as to the contractor, USAID staff, consultants and 
advisory groups may independently review and inspect research, and 
research processes and procedures involving human subjects, and based on 
such findings, the CHSO may prohibit research which presents 
unacceptable hazards or otherwise fails to comply with USAID procedures. 
Informed consent documents must include the stipulation that the 
subject's records may be subject to such review.
[61 FR 39095, July 26, 1996]



752.7013  Contractor-mission relationships.

    For use in all USAID contracts involving performance overseas. Note 
that paragraph (f) of this clause is applicable only in contracts with 
an educational institution.

               Contractor-Mission Relationships (Oct 1989)

    (a) The Contractor acknowledges that this contract is an important 
part of the United States Foreign Assistance Program and agrees that its 
operations and those of its employees in the Cooperating Country will be 
carried out in such a manner as to be fully commensurate with the 
responsibility which this entails.
    (b) The Mission Director is the chief representative of USAID in the 
Cooperating Country. In this capacity, he/she is responsible for both 
the total USAID program in the cooperating country including certain 
administrative responsibilities set forth in this contract, and for 
advising USAID regarding the performance of the work under the contract 
and its effect on the United States Foreign Assistance Program. Although 
the Contractor will be responsible for all professional, technical, and 
administrative details of the work called for by the contract, it shall 
be under the guidance of the Mission Director in matters relating to 
foreign policy. The Chief of Party shall keep the Mission Director 
currently informed of the progress of the work under the contract.
    (c) In the event the conduct of any Contractor employee is not in 
accordance with the preceding paragraphs, the Contractor's Chief of 
Party shall consult with the Mission Director and the employee involved 
and shall recommend to the Contractor a course of action with regard to 
such employee.
    (d) The parties recognize the right of the U.S. Ambassador to direct 
the removal from a country of any U.S. citizen or the discharge from 
this contract of any third-country national or cooperating-country 
national when, at the discretion of the Ambassador, the interests of the 
United States so require. Under these circumstances termination of an 
employee and replacement by an acceptable substitute shall be at no cost 
to USAID.
    (e) If it is determined that the services of such employee shall be 
terminated, the Contractor shall use its best efforts to cause the 
return of such employee to the United States or point of origin as 
appropriate.

[The following paragraph (f) is applicable if the contract is with an 
educational institution:]

    (f) It is understood by the parties that the Contractor's 
responsibilities shall not be restrictive of academic freedom. 
Notwithstanding these academic freedoms, the Contractor's employees, 
while in the Cooperating Country, are expected to show respect for its 
conventions, customs, and institutions, to abide by applicable laws and 
regulations, and not to interfere in its internal political affairs.

                             (End of clause)

[54 FR 46391, Nov. 3, 1989]



752.7014  Notice of changes in travel regulations.

    The following clause is for use in cost-reimbursement contracts 
involving work overseas.

           Notice of Changes in Travel Regulations (Jan. 1990)

    (a) Changes in travel, differential, and allowance regulations shall 
be effective on the beginning of the Contractor's next pay period 
following the effective date of the change as published in the 
applicable travel regulations (the Standardized Regulations (Government 
Civilians, Foreign Areas), the Uniform State/USAID/USIA Foreign Service 
Travel Regulations, and the Federal Travel Regulations).
    (b) The Standardized Regulations (Government Civilians Foreign 
Areas), and the Federal Travel Regulations are available from the 
Superintendent of Documents, U.S. Government Printing Office, 
Washington, DC 20402.
    (c) Information regarding the Uniform State/USAID/USIA Foreign 
Service Travel Regulations as referenced in the ``Travel and 
Transportation'' clause of this contract may be obtained from the 
Contracting Officer.

                             (End of clause)

[55 FR 6805, Feb. 27, 1990]

[[Page 74]]



752.7015  Use of pouch facilities.

    For use in all USAID non-commercial contracts exceeding the 
simplified acquisition threshold and involving performance overseas.

                   Use of Pouch Facilities (July 1997)

    (a) Use of diplomatic pouch is controlled by the Department of 
State. The Department of State has authorized the use of pouch 
facilities for USAID contractors and their employees as a general 
policy, as detailed in paragraphs (a)(1) through (a)(7) of this clause; 
however, the final decision regarding use of pouch facilities rests with 
the Embassy or USAID Mission. In consideration of the use of pouch 
facilities as hereinafter stated, the Contractor and its employees agree 
to indemnify and hold harmless the Department of State and USAID against 
loss or damage occurring in pouch transmission.
    (1) Contractors and their employees are authorized use of the pouch 
for transmission and receipt of up to a maximum of 2 pounds per shipment 
of correspondence and documents needed in the administration of foreign 
assistance programs.
    (2) U.S. citizen employeed of U.S. contractors are authorized use of 
the pouch for personal mail up to a maximum of one pound per shipment 
(but see paragraph (a)(3) of this clause).
    (3) Merchandise, parcels, magazines, or newspapers are not 
considered to be personal mail for purposes of this clause, and are not 
authorized to be sent or received by pouch.
    (4) Official mail as authorized by paragraph (a)(1) of this clause 
should be addressed as follows: Individual or Organization name, 
followed by the symbol ``C'', city Name of Post, U.S. Agency for 
International Development, Washington, DC 20523-0001.
    (5) Personal mail pursuant to paragraph (a)(2) of this clause should 
be sent to the address specified in paragraph (a)(4) of this clause, but 
without the name of the organization.
    (6) Mail sent via the diplomatic pouch may not be in violation of 
U.S. Postal laws and may not contain material ineligible for pouch 
transmission.
    (7) USAID contractor personnel are not authorized use of military 
postal facilities (APO/FPO). This is an Adjutant General's decision 
based on existing laws and regulations governing military postal 
facilities and is being enforced worldwide. Posts having access to APO/
FPO facilities and using such for diplomatic pouch dispatch, may, 
however, accept official mail from Contractors and letter mail from 
their employees for the pouch, provided of course, adequate postage is 
affixed.
    (b) The Contractor shall be responsible for advising its employees 
of this authorization and these guidelines and limitations on use of 
pouch facilities.
    (c) Specific additional guidance on use of pouch facilities in 
accordance with this clause is available from the Post Communication 
Center at the Embassy or USAID Mission.
[49 FR 13259, Apr. 3, 1984, as amended at 56 FR 2699, Jan. 24, 1991; 57 
FR 5237, Feb. 13, 1992; 62 FR 40471, July 29, 1997; 62 FR 45334, Aug. 
27, 1997]



752.7016  Family planning and population assistance activities.

    The following clause is applicable to all contracts involving any 
aspect of family planning or population activities.

    Family Planning and Population Assistance Activities (Aug. 1986)

    (a) Voluntary Participation. (1) The Contractor agrees to take any 
steps necessary to ensure that funds made available under this contract 
will not be used to coerce any individual to practice methods of family 
planning inconsistent with such individual's moral, philosophical, or 
religious beliefs. Further, the Contractor agrees to conduct its 
activities in a manner which safeguards the rights, health and welfare 
of all individuals who take part in the program.
    (2) Activities which provide family planning services or information 
to individuals, financed in whole or in part under this contract, shall 
provide a broad range of family planning methods and services available 
in the country which the activity is conducted or shall provide 
information to such individuals regarding where such methods and 
services may be obtained.
    (b) Prohibition on Abortion-related Activities. No funds made 
available under this Contract shall be used to finance, support, or be 
attributed to the following activities: (i) Procurement or distribution 
of equipment intended to be used for the purposes of inducing abortions 
as a method of family planning: (ii) special fees or incentives to women 
to coerce or motivate them to have abortions; (iii) payments to persons 
to perform abortions or to solicit persons to undergo abortions; (iv) 
information, education, training, or communication programs that seek to 
promote abortion as a method of family planning; (v) any biomedical 
research which relates, in whole or in part, to methods of, or the 
performance of, abortions or involuntary sterilization as a means of 
family planning (epidemiologic or descriptive research to assess the 
incidence, extent or consequences of abortion is not precluded); or (vi) 
lobbying for abortion.
    (c) Voluntary Participation Requirements for Sterilization Programs. 
(1) None of the funds

[[Page 75]]

made available under this contract shall be used to pay for the 
performance of involuntary sterilizations or to coerce or provide any 
financial incentive to any person to practice sterilizations.
    (2) The Contractor shall insure that any surgical sterilization 
procedures supported in whole or in part by funds from the contract are 
performed only after the individual has voluntarily come to the 
treatment facility and has given an informed consent to the 
sterilization procedure. Informed consent means the voluntary knowing 
assent from the individual given after being advised of the surgical 
procedures to be followed, the attendant discomforts and risks, the 
benefits to be expected, the availability of alternative methods of 
family planning, the purpose of the operation and its irreversibility, 
and the fact that the consent can be withdrawn at any time prior to the 
operation. An individual's consent is considered voluntary if it is 
based upon the exercise of free choice and is not obtained by any 
special inducement or any element of force, fraud, deceit, duress or 
other forms of coercion or misrepresentation.
    (3) Further, the Contractor shall document the patient's informed 
consent by: (i) A written consent document in a language the patient 
understands and speaks, which explains the basic elements of informed 
consent, as set out above, and which is signed by the individual and by 
the attending physician or by the authorized assistant of the attending 
physician; or (ii) when a patient is unable to read adequately a written 
certification signed by the attending physician or by the authorized 
assistant of the attending physician that the basic elements of informed 
consent above were orally presented to the patient, and that the patient 
thereafter consented to the performance of the operation. The receipt of 
the oral explanation shall be acknowledged by the patient's mark on the 
certification and by the signature or mark of the witness who shall be 
of the same sex and speak the same language as the patient.
    (4) Copies of the informed consent forms and certification documents 
for each voluntary sterilization (VS) procedure must be retained by the 
performing Contractor or subcontractor for a period of three years after 
the performance of the sterilization procedure.
    (d) The Contractor shall insert the substance of this clause in any 
subgrants, subcontracts, purchase orders, and other subordinate 
agreements hereunder whenever appropriate to the goods and services to 
be provided under such agreements.
[49 FR 13259, Apr. 3, 1984, as amended at 49 FR 33669, Aug. 24, 1984; 51 
FR 34985, Oct. 1, 1986]



752.7017  [Reserved]



752.7018  Health and accident coverage for USAID participant trainees.

    For use in any USAID contract under which USAID participants are 
trained.

 Health and Accident Coverage for USAID Participant Trainees (Oct. 1989)

    (a) The Contractor shall enroll all non-U.S. participants 
(hereinafter referred to as ``participants''), whose training in the 
U.S. is financed by USAID under this contract, in USAID's Health and 
Accident Coverage (HAC) program.
    (b) The Contractor shall, prior to the initiation of travel by each 
participant financed by USAID under this contract, fill out and mail to 
USAID the Participant Data Form (form USAID 1381-4). The contractor can 
obtain a supply of these cards and instructions for completing them, 
from the Human Capacity Development Center in the Bureau for Global 
Programs Field Support and Research (G/HCD0), USAID/W Washington, DC 
20523-1601.
    (c) The Contractor shall assure that enrollment shall begin 
immediately upon the participant's departure for the United States for 
the purpose of participating in a training program financed by USAID and 
that enrollment shall continue in full force and effect until the 
participant returns to his/her country of origin, or is released from 
USAID's responsibility, whichever is the sooner. The Contractor shall 
continue enrollment for participants whose departure is delayed due to 
medical or other compelling reasons, with the written concurrence of the 
USAID Project Manager and subject to the requirements of paragraph (d).
    (d) The Contractor shall submit the Participant Data Form to USAID, 
as specified in paragraph (b) of this section, to enable the 
participant(s), or the provider of medical services, to submit bills for 
medical costs resulting from illness and accident to the HAC 
Administrator (the name and address of the HAC Administrator may be 
obtained from either PFM/FM/CMP (see paragraph (d)(1) of this clause), 
or from the Human Capacity Development Center (see paragraph (b) of this 
clause).

The HAC Administrator, not the Contractor, shall be responsible for 
paying all reasonable and necessary charges, not otherwise covered by 
student health service or other insurance programs (see paragraphs (e) 
and (f)), subject to the availability of funds for such purposes, in 
accordance with the standards of coverage established by USAID under the 
HAC program, and subject to the payment of the fee specified in 
paragraph (d)(1), of this clause.

[[Page 76]]

    (1) Within thirty (30) days after enrollment, the Contractor shall 
send to: U.S. Agency for International Development, Office of Financial 
Management, Cash Management and Payment Division, Non-Project 
Assistance, Washington, DC 20523, an enrollment fee computed on the 
basis of the fixed rate per participant per month (information regarding 
the current rate is available from the USAID Human Capacity Development 
Center, or the HAC Administrator). The minimum period for calculation of 
fee is one month--that is, one participant month, 30 days, not one 
calendar month. Premiums may not be prorated for fractional periods of 
less than 30 days. The enrollment fee should cover a minimum period of 
up to one year or the current training period for which funds are 
obligated under this contract, whichever is less. As applicable, 
payments for additional periods of enrollment shall be made 30 days 
prior to the beginning of each new enrollment period or new period of 
funding of this contract. All such fee payments shall be made by check, 
payable to the ``U.S. Agency for International Development (HAC).'' If 
payments are not made within 30 days, a late payment charge shall apply 
at a percentage rate based on the current value of funds to the Treasury 
for each 30 day period; the full charge shall also be applicable to 
periods of less than 30 days. The percentage rate will be calculated by 
the Treasury as an average of the current value of funds to the Treasury 
for a recent three month period and will be transmitted to USAID in TFRM 
Bulletins.The late payment charge shall be applied to any portion of the 
fees in arrears and be remitted together with the fees as a separately 
identified item on the covering memorandum.
    (2) Whenever possible, fee payments for groups of several 
participants entering the HAC Program within the thirty-day reporting 
period shall be consolidated and covered by a single check. Participants 
covered by the fee payment shall be listed individually in a covering 
letter, identifying each participant (the name reported must be 
identical to that on the HAC enrollment card), showing period of 
enrollment (or period of coverage for which payment is remitted if this 
is different from the enrollment period), fee amount paid, contract 
number, and U.S. Government appropriation number (as shown under the 
``Accounting and Appropriation Data'' block of the cover page of the 
contract).
    (e) The Contractor, to the extent that it is an educational 
institution with a student health service program, shall also enroll all 
participants in their institution's student health service program. 
Medical costs which are covered under the institution's student health 
service shall not be eligible for payment under USAID's HAC program. The 
Contractor shall provide the HAC Administrator with a copy of 
information showing what medical costs are covered by the institution's 
student health service program; medical costs that are not covered by 
the institution's student health service program shall be submitted to 
the HAC Administrator.
    (f) If the Contractor has a mandatory, non-waivable health and 
accident insurance program for students, the costs of such insurance 
will be allowable under this contract. Any claims eligible under such 
insurance will not be payable under USAID's HAC plan or under this 
contract. Even though the participant is covered by the Contractor's 
mandatory, non-waivable health and accident insurance program, the 
participant MUST be enrolled in USAID's more comprehensive HAC program 
and HAC payments MUST be made to USAID as provided above. In addition, a 
copy of the mandatory insurance policy must be forwarded to the HAC 
Administrator.
    (g) Any payments for medical costs not covered by the Contractor's 
student health service program, or mandatory, non-
waivable health and accident insurance program, or USAID's HAC program 
shall be reimbursable under this contract only with specific written 
approval of the Contracting Office and subject to the availability of 
funds.
[49 FR 13259, Apr. 3, 1984, as amended at 49 FR 33669, Aug. 24, 1984; 54 
FR 46391, Nov. 3, 1989; 56 FR 2699, Jan. 24, 1991; 61 FR 39096, July 26, 
1996]



752.7019  Participant training.

    For use in any USAID direct contract involving training of USAID 
participants. Note that paragraphs (d) through (f) of this clause are 
applicable only when the contract is with an educational institution.

                    Participant Training (July 1996)

    (a) Definitions. (1) Participant training is the training of any 
foreign national outside of his or her home country, using USAID funds.
    (2) A Participant is any foreign national being trained under this 
contract outside of his or her country.
    (b) Applicable regulations. Proposals for contracts involving 
training of USAID participants, and participant training conducted under 
an USAID contract shall follow the policies established in Chapter 253 
of the USAID Automated Directive System (ADS)--``Training for 
Development Impact'' except to the extent that specific exceptions to 
ADS Chapter 253 have been provided in this contract. (Chapter 253 may be 
obtained by submitting a request to the Human Capacity

[[Page 77]]

Development Center (G/HCD), at the address specified in paragraph (c) of 
this section.)
    (c) Reporting requirement. Once each month the Contractor shall 
submit three copies of form USAID 1381-4, ``Participant Data Form'' to 
the Human Capacity Development Center (G/HCD) Bureau for Global Programs 
Field Support and Research, USAID, Washington, DC 20523-1601.

[The following paragraphs (d) through (f) are applicable if this 
contract is with an educational institution.]

    (d) To the extent foreign country national training is authorized in 
the schedule of this contract, the contractor shall be reimbursed for 
the following reasonable and allocable costs incurred in providing 
training and observation to participants in the United States or other 
approved location:
    (1) Customary tuition and fees of the institution in which the 
training takes place, as published in catalogs and announcements.
    (2) Cost of technical preparation and photocopying of papers and 
dissertations, allowances for required textbooks, the titles of which 
will be approved by the Contractor.
    (3) Travel within the United States or other countries (other than 
the country of the participant), as approved by the Contractor, 
including the cost of travel from port of entry into the United States 
to Contractor's campus to port of embarkation from the United States.
    (4) Subsistence while in the United States or in third countries not 
to exceed maximum USAID rates established in USAID Handbook 10, as from 
time to time amended.
    (5) Other direct costs authorized in the operational plan or 
otherwise determined by the Contracting Officer to be allowable in 
accordance with the general provisions clause of this contract entitled 
``Allowable Cost and Payment''.
    (e) Health and accident coverage for foreign-country nationals is 
governed by the clause of this contract entitled ``Health and Accident 
Coverage for USAID Participant Trainees.''
    (f) For participants assigned to the Contractor for whom 
specifically-designed courses not otherwise covered in paragraph (d)(1) 
of this clause are authorized, the Contractor shall be paid the 
following in lieu of the costs authorized in paragraph (d)(1) of this 
clause.
    (1) For not exceeding 20 instructional days (days on which such 
courses are scheduled to meet and are actually conducted):
    (i) One participant: $150 for the first day, and $50 per day for 
each additional day, up to 19 days.
    (ii) Groups up to and including 10 participants: for the first day, 
$150 for the first participant, and $50 for each additional participant. 
For each additional day, up to 19 days, $50 for each participant.
    (2) For more than 20 instructional days or more than 10 
participants: The Contractor shall submit a proposal including 
supporting cost and pricing data to the Contracting Officer for 
approval.

                             (End of clause)

[54 FR 46391, Nov. 3, 1989, as amended at 56 FR 2699, Jan. 24, 1991; 61 
FR 39096, July 26, 1996]



752.7020  [Reserved]



752.7021  Changes in tuition and fees.

    For use in contracts for participant training with an educational 
institution.

                 Changes in Tuition and Fees (Apr. 1984)

    While educational programs for participants will be established 
utilizing the Contractor's currently applicable tuition and fee 
schedule, the parties understand that such standard tuition and fees may 
be subject to change during the course of the program. If such event 
results in an increase in the cost of the program, USAID agrees to pay 
such increased standard tuition and fees in the next applicable academic 
term as a condition for the continuation of the program. If such change 
results in a decrease in the cost of the program, the Contractor agrees 
to charge to USAID only the amount of such revised standard tuition and 
fees in the next applicable academic term. The Contractor shall 
undertake to keep USAID currently advised as to changes in its standard 
tuition and fees. At such time as increases in the amounts of tuition 
and fees results in there being inadequate funds remaining in this 
contract to meet the costs of the next academic term, the Contractor 
will so advise USAID. USAID may then provide such additional funds as 
required to complete the program.



752.7022  Conflicts between contract and catalog.

    For use in contracts for participant training with an educational 
institution.

           Conflicts Between Contract and Catalog (Apr. 1984)

    In the event of any inconsistency between the provisions of this 
contract and any catalog, or other document incorporated in this 
contract by reference or otherwise or any of the Contractor's rules and 
regulations, the provisions of this contract shall govern.

[[Page 78]]



752.7023  Required visa form for USAID participants.

    For use in any USAID direct contract which involves training of 
USAID participants.

          Required Visa Form for USAID Participants (Apr. 1984)

    The Contractor shall insure that any foreign student brought to the 
United States for training under this contract uses visa form IAP 66A 
``Certificate for Exchange Visitor (J-1) Status''.



752.7024  Withdrawal of students.

    For use in contracts for participant training with an educational 
institution.

                   Withdrawal of Students (Apr. 1984)

    (a) The Government may, at its option and at any time, withdraw any 
student.
    (b) The Contractor may request withdrawal by the Government of any 
student for academic or disciplinary reasons.
    (c) If such withdrawal occurs prior to the end of a term, the 
Government shall pay any tuition and fees due for the current term in 
which the student may be enrolled, and the Contractor shall credit the 
Government with any charges eligible for refund under the Contractor's 
standard procedures for civilian students in effect on the effective 
date of such withdrawal.
    (d) Withdrawal of students by the Government shall not be the basis 
for any special charge or claim by the Contractor other than as provided 
by the Contractor's standard procedures.



752.7025  Approvals.

    For use in all USAID contracts.

                          Approvals (Apr. 1984)

    All approvals required to be given under the contract by the 
Contracting Officer or the Mission Director shall be in writing and, 
except when extraordinary circumstances make it impracticable, shall be 
requested by the Contractor sufficiently in advance of the contemplated 
action to permit approval, disapproval or other disposition prior to 
that action. If, because of existing conditions, it is impossible to 
obtain prior written approval, the approving official may, at his 
discretion, ratify the action after the fact.



752.7026  Reports.

    For use in all USAID contracts for technical or professional 
services.

                           Reports (Oct. 1989)

    (a) Reports required. The Contractor shall prepare the following 
reports:
    (1) A semi-annual, substantive report submitted within 45 days of 
the end of the period being covered, covering the status of the work 
under the contract, indicating progress, setting forth plans for the 
ensuing period, and including recommendations covering the current needs 
in the fields of activity covered under the terms of this contract.
    (2) [This paragraph (a)(2) is applicable to cost reimbursement 
contracts only.] A semi-annual, administrative report submitted within 
45 days of the end of the period being covered, covering expenditures by 
contract budget category, personnel employed under the contract, and 
foreign nationals being trained under the contract (if any).
    (3) A final report which summarizes the accomplishments of the 
assignment, methods of work used, and recommendations regarding 
unfinished work and/or program continuation. The final report shall be 
submitted within 60 days after completion of the work hereunder unless 
required date of submission is extended by the Contracting Officer.
    (4) Any other reports specified in the Schedule of this contract.
    (b) Distribution of reports. Copies of reports required under 
paragraph (a) shall be distributed as follows:
    (1) 3 copies to the Contracting Officer;
    (2) 4 copies to the Project Officer; and
    (3) 2 copies to the Bureau for Policy and Program Coordination, 
Center for Development Information and Evaluation, Office of Development 
Information, addressed as follows: PPC/CDIE/DI, ACQUISITIONS, Room 209, 
SA-18, U.S. Agency for International Development, Washington, DC 20523-
1802.
    (c) General. (1) The title page of all reports shall include a 
descriptive title, the author's name(s), contract number, project number 
and title, contractor's name, name of the USAID project office, and the 
publication or issuance date of the report.
    (2) When preparing reports, the contractor shall refrain from using 
elaborate art work, multicolor printing and expensive paper/binding, 
unless it is specifically authorized in the Contract Schedule. Wherever 
possible, pages should be printed on both sides using single spaced 
type.

                             (End of clause)

[54 FR 46392, Nov. 3, 1989, as amended at 56 FR 2699, Jan. 24, 1991; 56 
FR 67226, Dec. 30, 1991; 59 FR 33447, June 29, 1994]



752.7027  Personnel.

    For use in all USAID services contracts involving performance 
overseas. Note that paragraphs (f) and (g) of this

[[Page 79]]

clause are for use only in cost reimbursement contracts.

                          Personnel (Dec. 1990)

    (a) Clearance.
    (1) Individuals Engaged or Assigned Within the United States. The 
contractor will obtain written notification from the Contracting Officer 
of Cooperating Country clearance of any employee sent outside the United 
States to perform duties under this contract.
    (2) Individuals Engaged or Assigned When Outside the United States. 
No individual shall be engaged or assigned when outside the United 
States to perform work outside the United States under this contract 
unless authorized in the schedule or otherwise approved by the 
Contracting Officer or Mission Director. However, when services are 
performed in the Cooperating Country on a casual or irregular basis or 
in an emergency, exception to this provision can be made in accordance 
with instructions or regulations established by the Mission Director.
    (b) Physical fitness of employees and dependents. See the clause of 
this contract entitled Physical Fitness.
    (c) Conformity to laws and regulations of Cooperating Country. 
Contractor agrees to use its best efforts to assure that its employees 
and their dependents, while in the Cooperating Country, abide by all 
applicable laws and regulations of the Cooperating Country and political 
subdivisions thereof.
    (d) Importation or sale of personal property or automobiles. To the 
extent permitted by Cooperating Country laws, the importation and sale 
of personal property or automobiles by contractor employees and their 
dependents in the Cooperating Country shall be subject to the same 
limitations and prohibitions which apply to U.S. nationals employed by 
the Mission. This provision does not apply to employees or consultants 
who are citizens or legal residents of the Cooperating Country.
    (e) Economic and Financial Activities. Other than work to be 
performed under this contract for which an employee or consultant is 
assigned by the contractor, no such employee or consultant of the 
contractor shall engage, directly or indirectly, either in his/her own 
name or in the name or through the agency of another person, in any 
business, profession or occupation in the Cooperating Country or other 
foreign countries to which he/she is assigned, nor shall he make loans 
or investments to or in any business, profession or occupation in the 
Cooperating Country or other foreign countries in which he/she is 
assigned. This provision does not apply to employees or consultants who 
are citizens or legal residents of the Cooperating Country.

    [The following paragraphs (f) and (g) are applicable only to cost 
reimbursement contracts.]

    (f) Duration of Appointments. (1) Regular employees will normally be 
appointed for a minimum of 2 years which period includes orientation 
(less language training) in the United States and authorized 
international travel under the contract except:
    (i) An appointment may be made for less than 2 years if the contract 
has less than 2 years but more than 1 year to run provided that if the 
contract is extended the appointment shall also be extended to the full 
2 years. This provision shall be reflected in the employment agreement 
prior to employment under this contract.
    (ii) When a 2-year appointment is not required, appointment may be 
made for less than 2 years but in no event less than 1 year.
    (iii) When the normal tour of duty established for USAID personnel 
at a particular post is less than 2 years, then a normal appointment 
under this contract may be of the same duration.
    (iv) When the contractor is unable to make appointments of regular 
employees for a full 2 years, the contractor may make appointments of 
less than 2 but not less than 1 year, provided that such appointment is 
approved by the Contracting Officer.
    (2) Services required for less than 1 year will be considered short-
term appointments and the employee will be considered a short-term 
employee.
    (g) Employment of Dependents. If any person who is employed for 
services in the Cooperating Country under this contract is either (1) a 
dependent of an employee of the U.S. Government working in the 
Cooperating Country, or (2) a dependent of a contractor employee working 
under a contract with the U.S. Government in the Cooperating Country, 
such person shall continue to hold the status of a dependent. He or she 
shall be entitled to salary for the time services are actually performed 
in the Cooperating Country, and differential and allowances as 
established by the Standardized Regulations (Government Civilians, 
Foreign Areas).

                             (End of clause)

[56 FR 7587, Feb. 25, 1991, as amended at 62 FR 40471, July 29, 1997]



752.7028  Differential and allowances.

    The following clause is for use in all USAID cost reimbursement 
contracts performed in whole or in part overseas.

                Differentials and Allowances (July 1996)

    (This clause does not apply to TCN or CCN employees. TCN and CCN 
employees are not eligible for differentials and allowances, unless 
specifically authorized by the cognizant Assistant Administrator or 
Mission Director.

[[Page 80]]

A copy of such authorization shall be retained and made available as 
part of the contractor's records which are required to be preserved and 
made available by the ``Examination of Records by the Comptroller 
General'' and ``Audit'' clauses of this contract).

    (a) Post differential. Post differential is an additional 
compensation for service at places in foreign areas where conditions of 
environment differ substantially from conditions of environment in the 
continental United States and warrant additional compensation as a 
recruitment and retention incentive. In areas where post differential is 
paid to USAID direct-hire employees, post differential not to exceed the 
percentage of salary as is provided such USAID employees in accordance 
with the Standardized Regulations (Government Civilians, Foreign Areas), 
Chapter 500 (except the limitation contained in Section 552, ``Ceiling 
on Payment'') Tables-Chapter 900, as from time to time amended, will be 
reimbursable hereunder for employees in respect to amounts earned during 
the time such employees actually spend overseas on work under this 
contract. When such post differential is provided to regular employees 
of the Contractor, it shall be payable beginning on the date of arrival 
at the post of assignment and continue, including periods away from post 
on official business, until the close of business on the day of 
departure from post of assignment en route to the United States. Sick or 
vacation leave taken at or away from the post of assignment will not 
interrupt the continuity of the assignment or require a discontinuance 
of such post differential payments, provided such leave is not taken 
within the United States or the territories of the United States. Post 
differential will not be payable while the employee is away from his/her 
post of assignment for purposes of home leave. Short-term employees 
shall be entitled to post differential beginning with the forty-third 
(43rd) day at post.
    (b) Living quarters allowance. Living quarters allowance is an 
allowance granted to reimburse an employee for substantially all of his/
her cost for either temporary or residence quarters whenever Government-
owned or Government-rented quarters are not provided to him/her at his/
her post without charge. Such costs are those incurred for temporary 
lodging (temporary lodging allowance) or one unit of residence quarters 
(living quarters allowance) and include rent, plus any costs not 
included therein for heat, light, fuel, gas, electricity and water. The 
temporary lodging allowance and the living quarters allowance are never 
both payable to an employee for the same period of time. The Contractor 
will be reimbursed for payments made to employees for a living quarters 
allowance for rent and utilities if such facilities are not supplied. 
Such allowance shall not exceed the amount paid USAID employees of 
equivalent rank in the Cooperating Country, in accordance with either 
the Standardized Regulations (Government Civilians, Foreign Areas), 
Chapter 130, as from time to time amended, or other rates approved by 
the Mission Director. Subject to the written approval of the Mission 
Director, short-term employees may be paid per diem (in lieu of living 
quarters allowance) at rates prescribed by the Federal Travel 
Regulations, as from time to time amended, during the time such short-
term employees spend at posts of duty in the Cooperating Country under 
this contract. In authorizing such per diem rates, the Mission Director 
shall consider the particular circumstances involved with respect to 
each such short-term employee including the extent to which meals and/or 
lodging may be made available without charge or at nominal cost by an 
agency of the United States Government or of the Cooperating Government, 
and similar factors.
    (c) Temporary quarters subsistence allowance. Temporary quarters 
subsistence allowance is a quarters allowance granted to an employee for 
the reasonable cost of temporary quarters incurred by the employee and 
his family for a period not in excess of (i) 90 days after first arrival 
at a new post in a foreign area or a period ending with the occupation 
of residence (permanent) quarters, if earlier, and (ii) 30 days 
immediately preceding final departure from the post subsequent to the 
necessary vacating of residence quarters, unless an extension is 
authorized in writing by the Mission Director. The Contractor will be 
reimbursed for payments made to employees and authorized dependents for 
temporary quarters subsistence allowance, in lieu of living quarters 
allowance, not to exceed the amount set forth in the Standardized 
Regulations (Government Civilians, Foreign Areas), Chapter 120, as from 
time to time amended.
    (d) Post allowance. Post allowance is a cost-of-living allowance 
granted to an employee officially stationed at a post where the cost of 
living, exclusive of quarters cost, is substantially higher than in 
Washington, DC. The Contractor will be reimbursed for payments made to 
employees for post allowance not to exceed those paid USAID employees in 
the Cooperating Country, in accordance with the Standardized Regulations 
(Government Civilians, Foreign Areas), Chapter 220, as from time to time 
amended.
    (e) Supplemental post allowance. Supplemental post allownce is a 
form of post allowance granted to an employee at his/her post when it is 
determined that assistance is necessary to defray extraordinary 
subsistence costs. The Contractor will be reimbursed for payments made 
to employees for supplemental post allowance not to exceed the

[[Page 81]]

amount set forth in the Standardized Regulations (Government Civilians, 
Foreign Areas), Chapter 230, as from time to time amended.
    (f) Educational allowance. Educational allowance is an allowance to 
assist an employee in meeting the extraordinary and necessary expenses, 
not otherwise compensated for, incurred by reason of his/her service in 
a foreign area in providing adequate elementary and secondary education 
for his/her children. The Contractor will be reimbursed for payments 
made to regular employees for educational allowances for their dependent 
children in amounts not to exceed those set forth in the Standardized 
(Regulations Government Civilians, Foreign Areas), Chapter 270, as from 
time to time amended.
    (g) Educational travel. Educational travel is travel to and from a 
school in the United States for secondary education (in lieu of an 
educational allowance) and for college education. The Contractor will be 
reimbursed for payments made to regular employees for educational travel 
for their dependent children provided such payment does not exceed that 
which would be payable in accordance with the Standardized Regulations 
(Government Civilians, Foreign Areas), Chapter 280, as from time to time 
amended. Educational travel shall not be authorized for regular 
employees whose assignment is less than two years.
    (h) Separate maintenance allowance. Separate maintenance allowance 
is an allowance to assist an employee who is compelled, by reason of 
dangerous, notably unhealthful, or excessively adverse living conditions 
at his/her post of assignment in a foreign area, or for the convenience 
of the Government, to meet the additional expense of maintaining his/her 
dependents elsewhere than at such post. The Contractor will be 
reimbursed for payments made to regular employees for a separate 
maintenance allowance not to exceed that made to Aid employees in 
accordance with the Standardized Regulations (Government Civilians, 
Foreign Areas), Chapter 260, as from time to time amended.
    (i) Payments during evacuation. The Standardized Regulations 
(Government Civilians, Foreign Areas) provide the authority for 
efficient, orderly, and equitable procedure for the payment of 
compensation, post differential and allowances in the event of an 
emergency evacuation of employees or their dependents, or both, from 
duty stations for military or other reasons or because of imminent 
danger to their lives. If evacuation has been authorized by the Mission 
Director the Contractor will be reimbursed for payments made to 
employees and authorized dependents evacuated from their post of 
assignment in accordance with the Standardized Regulations (Government 
Civilians, Foreign Areas), Chapter 600, and the Federal Travel 
Regulations, as from time to time amended.
    (j) Danger pay allowance. (1) The contractor will be reimbursed for 
payments made to its employees for danger pay not to exceed that paid 
USAID employees in the cooperating country, in accordance with the 
Standardized Regulations (Government Civilians, Foreign Areas), Chapter 
650, as from time to time amended.
    (2) Danger pay is an allowance that provides additional compensation 
above basic compensation to an employee in a foreign area where civil 
insurrection, civil war, terrorism or wartime conditions threaten 
physical harm or imminent danger to the health or well-being of the 
employee. The danger pay allowance is in lieu of that part of the post 
differential which is attributable to political violence. Consequently, 
the post differential may be reduced while danger pay is in effect to 
avoid dual crediting for political violence.
[49 FR 13259, Apr. 3, 1984, as amended at 51 FR 11450, Apr. 3, 1986; 53 
FR 50632, Dec. 16, 1988; 61 FR 39096, July 26, 1996; 61 FR 51235, Oct. 
1, 1996]



752.7029  Post privileges.

    For use in all USAID non-commercial contracts involving performance 
overseas.

                       Post Privileges (July 1993)

    (a) Routine health room services may be available, subject to post 
policy, to U.S. citizen contractors and their authorized dependents 
(regardless of citizenship) at the post of duty. These services do not 
include hospitalization, or predeparture or end of tour medical 
examinations. The services normally include such medications as may be 
available, immunizations and preventive health measures, diagnostic 
examinations and advice, and home visits as medically indicated. 
Emergency medical treatment is provided to U.S. citizen employees and 
dependents, whether or not they may have been granted access to routine 
health room services, on the same basis as it would be to any U.S. 
citizen in an emergency medical situation in the country.
    (b) Privileges such as the use of APO, PX's, commissaries, and 
officer's clubs are established at posts abroad pursuant to agreements 
between the U.S. and Cooperating Governments. These facilities are 
intended for and usually limited to members of the official U.S. 
establishment including the Embassy, USAID Mission, U.S. Information 
Service, and the Military. Normally, the

[[Page 82]]

agreements do not permit these facilities to be made available to 
nonofficial Americans.
[49 FR 13259, Apr. 3, 1984, as amended at 56 FR 7587, Feb. 25, 1991; 58 
FR 58596, Nov. 2, 1993; 62 FR 40471, July 29, 1997]



752.7030  Inspection trips by contractor's officers and executives.

    For use in cost reimbursement contracts with an educational 
institution involving performance overseas.

  Inspection Trips by Contractor's Officers and Executives (Apr. 1984)

    Provided it is approved by the Mission Director, the Contractor may 
send the Campus Coordinator, a professional member of its staff as an 
alternate to the Campus Coordinator, or such of its senior officials 
(e.g., president, vice presidents, deans, or department heads) to the 
Cooperating Country as may be required to review the progress of the 
work under this contract. Except for the Campus Coordinator or his/her 
alternate, no direct salary charges will be paid hereunder with respect 
to any such officials.



752.7031  Leave and holidays.

    For use in all USAID cost-reimbursement contracts for technical or 
professional services.

                     Leave and Holidays (Oct. 1989)

    (a) Vacation leave. (1) The Contractor may grant to its employees 
working under this contract vacations of reasonable duration in 
accordance with the Contractor's practice for its employees, but in no 
event shall such vacation leave be earned at a rate exceeding 26 work 
days per annum. Reimbursement for vacation leave is limited to the 
amount earned by employees while serving under this contract.
    For regular employees during their tour of duty in the Cooperating 
Country, vacation leave is provided under this contract primarily for 
purposes of affording necessary rest and recreation. The Contractor's 
Chief of Party, the employee and the Cooperating Country institution 
associated with this project shall develop vacation leave schedules 
early in the employee's tour of duty taking into consideration project 
requirements, employee preference and other factors.
    (2) Leave taken during the concluding weeks of an employee's tour 
shall be included in the established leave schedule and be limited to 
that amount of leave which can be earned during a twelve-month period 
unless approved in accordance with paragraph (a)(3) of this clause.
    (3) Vacation leave earned but not taken by the end of the employee's 
tour pursuant to paragraphs (a) (1) and (2) of this clause will be 
forfeited unless the requirements of the project precluded the employee 
from taking such leave, and the Contracting Officer (with the 
endorsement of the Mission) approves one of the following as an 
alternative:
    (i) Taking, during the concluding weeks of the employee's tour, 
leave not permitted under (a)(2) of this section, or
    (ii) Lump-sum payment for leave not taken provided such leave does 
not exceed the number of days which can be earned by the employee during 
a twelve-month period.
    (b) Sick Leave. Sick leave is earned by employees in accordance with 
the Contractor's usual practice but not to exceed 13 work days per annum 
or 4 hours every 2 weeks. Additional sick leave after use of accrued 
vacation leave may be advanced in accordance with Contractor's usual 
practice, if in the judgment of the Contractor's Chief of Party it is 
determined that such additional leave is in the best interest of the 
project. In no event shall such additional leave exceed 30 days. The 
Contractor agrees to reimburse USAID for leave used in excess of the 
amount earned during the employee's assignment under this contract. Sick 
leave earned and unused at the end of a regular tour of duty may be 
carried over to an immediately-succeeding tour of duty under this 
contract. The use of home leave authorized under this clause shall not 
constitute a break in service for the purpose of sick leave carry-over. 
Contractor employees will not be compensated for unused sick leave at 
the completion of their duties under this contract.
    (c) Home leave. (1) Home leave is leave earned for service abroad 
for use only in the United States, in the Commonwealth of Puerto Rico, 
or in the possessions of the United States.
    (2) A regular employee who is a U.S. citizen or resident and has 
served at least 2 years overseas, as defined in paragraph (c)(4) of this 
clause, under this contract and has not taken more than 30 workdays 
leave (vacation, sick, or leave without pay) in the United States, may 
be granted home leave of not more than 15 workdays for each such year of 
service overseas, provided that such regular employee agrees to return 
overseas upon completion of home leave under an additional 2 year 
appointment, or for a shorter period of not less than 1 year of overseas 
service under the contract if the Mission Director has approved in 
advance. Home leave must be taken in the United States, the Commonwealth 
of Puerto Rico, or the possessions of the United States; any days spent 
elsewhere will be charged to vacation leave or leave without pay.
    (3) Notwithstanding the requirement in paragraph (c)(2), of this 
clause, that the Contractor's regular employee must have served 2 years 
overseas under this contract to be eligible for home leave, Contractor 
may grant

[[Page 83]]

advance home leave to such regular employee subject to all of the 
following conditions:
    (i) Granting of advance home leave would in each case serve to 
advance the attainment of the objectives of this contract;
    (ii) The regular employee shall have served a minimum of 18 months 
in the Cooperating Country on his/her current tour of duty under this 
contract; and
    (iii) The regular employee shall have agreed to return to the 
Cooperating Country to serve out the remainder of his/her current tour 
of duty and an additional 2 year appointment under this contract, or 
such other additional appointment of not less than 1 year of overseas 
service as the Mission Director may approve.
    (4) The period of service overseas required under paragraph (c)(2) 
or paragraph (c)(3) of this clause shall include the actual days spent 
in orientation in the United States (less language training) and the 
actual days overseas beginning on the date of departure from the United 
States port of embarkation on international travel and continuing, 
inclusive of authorized delays en route, to the date of arrival at the 
United States port of debarkation from international travel. Allowable 
vacation and sick leave taken while overseas, but not leave without pay, 
shall be included in the required period of service overseas. An amount 
equal to the number of days vacation and sick leave taken in the United 
States, the Commonwealth of Puerto Rico, or the possessions of the 
United States will be added to the required period of service overseas.
    (5) Salary during travel to and from the United States for home 
leave will be limited to the time required for travel by the most 
expeditious air route. The Contractor will be responsible for 
reimbursing USAID for salary payments made during home leave if in spite 
of the undertaking of the new appointment the regular employee, except 
for reasons beyond his/her control as determined by the Contracting 
Officer, does not return overseas and complete the additional required 
service. Unused home leave is not reimbursable under this contract.
    (6) To the extent deemed necessary by the Contractor, regular 
employees in the United States on home leave may be authorized to spend 
not more than 5 days in work status for consultation at home office/
campus or at USAID/Washington before returning to their post of duty. 
Consultation at locations other than USAID/Washington or home office/
campus, as well as any time in excess of 5 days spent for consultation, 
must be approved by the Mission Director or the Contracting Officer.
    (7) Except as provided in the schedule or approved by the Mission 
Director or the Contracting Officer, home leave is not authorized for 
TCN or CCN employees.
    (d) Holidays. Holidays for Contractor employees serving in the 
United States shall be in accordance with the Contractor's established 
policy and practice. Holidays for Contractor employees serving overseas 
should take into consideration local practices and shall be established 
in collaboration with the Mission Director.
    (e) Military leave. Military leave of not more than 15 calendar days 
in any calendar year may be granted in accordance with the Contractor's 
usual practice to each regular employee whose appointment is not limited 
to 1 year or less and who is a reservist of the United States Armed 
Forces, provided that such military leave has been approved in advance 
by the cognizant Mission Director or Assistant Administrator. A copy of 
any such approval shall be provided to the Contracting Officer.
    (f) Leave Records. The Contractor's leave records shall be preserved 
and made available as part of the contractor's records which are 
required to be preserved and made available by the Examination of 
Records by the Comptroller General and Audit clauses of this contract.

                             (End of clause)

[54 FR 46392, Nov. 3, 1989, as amended at 56 FR 2699, Jan. 24, 1991]



752.7032  International travel approval and notification requirements.

    For use in any USAID contract requiring international travel.

 International Travel Approval and Notification Requirements (Jan. 1990)

    Prior written approval by the Contracting Officer is required for 
all interrnational travel directly and identifiably funded by USAID 
under this contract. The Contractor shall therefore present to the 
Contracting Officer an itinerary for each planned international trip, 
showing the name of the traveler, purpose of the trip, origin/
destination (and intervening stops), and dates of travel, as far in 
advanced of the proposed travel as possible, but in no event less than 
three weeks before travel is planned to commence. The Contracting 
Officer's prior written approval may be in the form of a letter or 
telegram or similar device or may be specifically incorporated into the 
schedule of the contract. At least one week prior to commencement of 
approved international travel, the Contractor shall notify the cognizant 
Mission, with a copy to the Contracting Officer, of planned travel, 
identifying the travellers and the dates and times of arrival.

                             (End of clause)

[55 FR 6805, Feb. 27, 1990]

[[Page 84]]



752.7033  Physical fitness.

    For use in all USAID contracts involving performance overseas.

                      Physical Fitness (July 1997)

    (The requirements of this provision do not apply to employees hired 
in the Cooperating Country or to authorized dependents who were already 
in the Cooperating Country when their sponsoring employee was hired.)
    (a) Assignments of less than 60 days in the Cooperating Country. The 
contractor shall require employees being assigned to the Cooperating 
Country for less than 60 days to be examined by a licensed doctor of 
medicine. The contractor shall require the doctor to provide to the 
contractor a written statement that in his/her medical opinion the 
employee is physically qualified to engage in the type of activity for 
which he/she is employed and the employee is physically able to reside 
in the country to which he/she is assigned. Under a cost reimbursement 
contract, if the contractor has no written statement of medical opinion 
on file prior to the departure for the Cooperating Country of any 
employee and such employee is unable to perform the type of activity for 
which he/she is employed or cannot complete his/her tour of duty because 
of any physical disability (other than physical disability arising from 
an accident while employed under this contract), the contractor shall be 
responsible for returning the disabled employee to his/her point of hire 
and providing a replacement at no additional cost to the Government. In 
addition, in the case of a cost reimbursement contract, the contractor 
shall not be entitled to reimbursement for any additional costs 
attributable to delays or other circumstances caused by the employee's 
inability to complete his/her tour of duty.
    (b) Assignments of 60 days or more in the Cooperating Country. (1) 
The Contracting Officer shall provide the contractor with a reproducible 
copy of the ``USAID Contractor Employee Physical Examination Form''. 
This form is for collection of information; it has been reviewed and 
approved by OMB (see 701.105(a)). Information required by the Paperwork 
Reduction Act for reporting the burden estimate, the points of contact 
regarding burden estimate, and the OMB approval expiration date, are 
printed on the form. The contractor shall reproduce the form as 
required, and provide a copy to each employee and authorized dependent 
proposed for assignments of 60 days or more in the Cooperating Country. 
The contractor shall have the employee and all authorized dependents 
obtain a physical examination from a licensed physician, who will 
complete the form for each individual. The employee will deliver the 
physical examination form(s) to the embassy health unit in the 
Cooperating Country.
    (2) (The following information is provided for two purposes: To 
assist fixed price offerors to develop their price proposal, and to 
provide cost reimbursement contractors with guidance in determining 
reasonable and allowable costs.) As a contribution to the cost of 
medical examinations, USAID shall reimburse the contractor for the 
physical examination authorized in paragraph (a) of this section in an 
amount not to exceed $100 for the physical examination, plus 
reimbursement of charges for immunizations to the extent not covered by 
the contractor's health insurance policy. For physical examinations 
authorized in paragraph (b)(1) above, the USAID contribution to the cost 
of the examination shall be as follows:
    (i) For the employee and authorized dependents 12 years of age and 
over, one half of the cost of each examination up to a maximum USAID 
share of $300 per individual, plus reimbursement of charges for 
immunizations to the extent not covered by the contractor's health 
insurance policy.
    (ii) For authorized dependents under 12 years of age, one half of 
the cost of each examination up to a maximum USAID share of $120 per 
individual, plus reimbursement of charges for immunizations to the 
extent not covered by the contractor's health insurance policy.
    (iii) The contractor must obtain the prior written approval of the 
Contracting Officer to receive any USAID contributions higher than these 
limits.

                             (End of clause)

[56 FR 7588, Feb. 25, 1991, as amended at 58 FR 58596, Nov. 2, 1993; 62 
FR 40471, July 29, 1997; 62 FR 45334, Aug. 27, 1997]



752.7034  Acknowledgement and disclaimer.

    For use in any USAID contract which funds or partially funds 
publications, videos, or other information/media products.

                Acknowledgement and Disclaimer (Dec 1991)

    (a) USAID shall be prominently acknowledged in all publications, 
videos or other information/media products funded or partially funded 
through this contract, and the product shall state that the views 
expressed by the author(s) do not necessarily reflect those of USAID. 
Acknowledgements should identify the sponsoring USAID Office and Bureau 
or Mission as well as the U.S. Agency for International Development 
substantially as follows:
    ``This (publication, video or other information/media product 
(specify)) was made possible through support provided by the Office of 
______, Bureau for ______, U.S. Agency for

[[Page 85]]

International Development, under the terms of Contract No. ______. The 
opinions expressed herein are those of the author(s) and do not 
necessarily reflect the views of the U.S. Agency for International 
Development.''
    (b) Unless the contractor is instructed otherwise by the cognizant 
technical office, publications, videos or other information/media 
products funded under this contract and intended for general readership 
or other general use will be marked with the USAID logo and/or U.S. 
AGENCY FOR INTERNATIONAL DEVELOPMENT appearing either at the top or at 
the bottom of the front cover or, if more suitable, on the first inside 
title page for printed products, and in equivalent/appropriate location 
in videos or other information/media products. Logos and markings of co-
sponsors or authorizing institutions should be similarly located and of 
similar size and appearance.

                             (End of clause)

[57 FR 5237, Feb. 13, 1992]



752.7035  Public notices.

    The following clause is for use when the cognizant technical office 
determines that the contract is of public interest, and that both the 
public and the Government would benefit from public notices concerning 
the contract, and requests that the Contracting Officer include the 
clause in the contract.

                        Public Notices (Dec 1991)

    It is USAID's policy to inform the public as fully as possible of 
its programs and activities. The contractor is encouraged to give public 
notice of the receipt of this contract and, from time to time, to 
announce progress and accomplishments. Press releases or other public 
notices should include a statement substantially as follows: ``The U.S. 
Agency for International Development administers the U.S. foreign 
assistance program providing economic and humanitarian assistance in 
more than 80 countries worldwide.'' The contractor may call on USAID's 
Legislative and Public Affairs (LPA) for advice regarding public 
Notices. The contractor is requested to provide copies of notices or 
announcements to the cognizant technical officer and to USAID's 
Legislative and Public Affairs (LPA) as far in advance of release 
aspossible.

                             (End of clause)

[57 FR 5237, Feb. 13, 1992, as amended at 60 FR 11913, Mar. 3, 1995]



           Subpart 752.3-70--USAID Clause Matrices  (Reserved)



PART 753--FORMS--Table of Contents




                         Subpart 753.1--General

753.107  Obtaining forms.

                  Subpart 753.2--Prescription of Forms

753.270  Prescription of USAID Forms.

                  Subpart 753.3--Illustration of Forms

753.300  Scope of subpart.

    Authority:  Sec. 621, Pub. L. 87-195, 75 Stat. 445 (22 U.S.C. 2381), 
as amended; E.O. 12163, Sept. 29, 1979 44 FR 56673, 3 CFR, 1979 Comp., 
p. 435.

    Source:  53 FR 50632, Dec. 16, 1988, unless otherwise noted.



                         Subpart 753.1--General



753.107  Obtaining forms.

    Copies of any USAID Form referenced in the AIDAIR may be obtained 
from the U.S. Agency for International Development, Washington, DC 
20523-0001, Attention: M/AS/ISS, Distribution, Room B-929 N.S., or from 
the congnizant Contracting Officer.
[53 FR 50632, Dec. 16, 1988, as amended at 56 FR 2699, Jan. 24, 1991; 56 
FR 67226, Dec. 30, 1991; 59 FR 33447, June 29, 1994; 62 FR 40471, July 
29, 1997]



                  Subpart 753.2--Prescription of Forms



753.270  Prescription of USAID forms.

    The requirements for use of USAID forms are contained in parts 701 
through 752 where the subject matter applicable to the form is 
addressed.



                  Subpart 753.3--Illustration of Forms



753.300  Scope of subpart.

    USAID forms are not illustrated in the AIDAR. Copies of any USAID 
form prescribed in the AIDAR may be obtained as provided in 753.107.

[[Page 86]]

                         Appendices to Chapter 7

                          Appendix A [Reserved]

                          Appendix B [Reserved]

                          Appendix C [Reserved]

    APPENDIX D--DIRECT USAID CONTRACTS WITH A U.S. CITIZEN OR A U.S. 
               RESIDENT ALIEN FOR PERSONAL SERVICES ABROAD

    1. General. (a) Purpose. This appendix sets forth the authority, 
policy, and procedures under which USAID contracts with a U.S. citizen 
or U.S. resident alien for personal services abroad.
    (b) Definitions. (1) Personal services contract (PSC) means a 
contract that, by its express terms or as administered, make the 
contractor personnel appear, in effect, Government employees (see FAR 
37.104).
    (2) Employer-employee relationship means an employment relationship 
under a service contract with an individual which occurs when, as a 
result of the contract's terms or the manner of its administration 
during performance, the contractor is subject to the relatively 
continuous supervision and control of a Government officer or employee.
    (3) Non-person services contract means a contract under which the 
personnel rendering the services are not subject either by the 
contract's terms or by the manner of its administration, to the 
supervision and control usually prevailing in relationships between the 
Government and its employees.
    (4) Independent contractor relationship means a contract 
relationship in which the contractor is not subject to the supervision 
and control prevailing in relationships between the Government and its 
employees. Under this relationship, the Government does not normally 
supervise the performance of the work, control the days of the week or 
hours of the day in which it is to be performed, or the location of 
performance.
    (5) Resident hire means a U.S. citizen who, at the time of hire as a 
PSC, resides in the cooperating country as a spouse or dependent of a 
U.S. citizen employed by a U.S. government agency or under any U.S. 
government-financed contract or agreement, or for reasons other than for 
employment with a U.S. government agency or under any U.S. government-
financed contract or agreement. A U.S. citizen for purposes of this 
definition also includes persons who at the time of contracting are 
lawfully admitted permanent residents of the United States.
    (6) U.S. resident alien means a non-U.S. citizen lawfully admitted 
for permanent residence in the United States.
    (7) Abroad means outside the United States and its territories and 
possessions.
    (8) USAID direct-hire employees means civilian employees appointed 
under USAID Handbook 25 procedures or superseding Automated Directive 
System (ADS) Chapters.

    2. Legal Basis. (a) Section 635(b) of the Foreign Assistance Act of 
1961, as amended (hereinafter referred to as the ``FAA'') provides the 
Agency's contracting authority.
    (b) Section 636(a)(3) of the FAA (22 U.S.C. 2396(a)(3)) authorizes 
the Agency to enter into personal services contracts with individuals 
for personal services abroad and provides further that such individuals 
``* * * shall not be regarded as employees of the U.S. Government for 
the purpose of any law administered by the Civil Service Commission.'' 
\1\
---------------------------------------------------------------------------

    \1\ The Civil Service Commission is now the Federal Office of 
Personnel Management.

    3. Applicability. (a) This appendix applies to all personal services 
contracts with U.S. citizens or U.S. resident aliens to provide 
assistance abroad under Section 636(a)(3) of the FAA.
    (b) This appendix does not apply to:
    (1) Nonpersonal services contracts with U.S. citizens or U.S. 
resident aliens; such contracts are covered by the basic text of the FAR 
(48 CFR Chapter 1) and the AIDAR (48 CFR Chapter 7).
    (2) Personal services contracts with individual Cooperating Country 
Nationals (CCNs) or Third Country Nationals (TCNs). Such contracts are 
covered by Appendix J of this chapter.
    (3) Other personal services arrangements covered by USAID Handbook 
25--Employment and Promotion or superseding ADS Chapters.
    (4) Interagency agreements (e.g., PASAs and RSSAs covered by ADS 
306--Interagency Agreements.

    4. Policy. (a) General. USAID may finance, with either program or 
operating expense (OE) funds, the cost of personal services contracts as 
part of the Agency's program of foreign assistance by entering into a 
direct contract with an individual U.S. citizen or U.S. resident alien 
for personal services abroad.
    (1) Program funds. Under the authority of Section 635(h) of the FAA, 
program funds may be obligated for periods up to five years where 
necessary and appropriate to the accomplishment of the tasks involved.
    (2) Operating Expense Funds. Pursuant to USAID budget policy, OE 
funded salaries and other recurrent cost items may be forward funded for 
a period of up to three (3) months beyond the fiscal year in which these 
funds were obligated. Non-recurring cost items

[[Page 87]]

may be forward funded for periods not to exceed twenty-four (24) months 
where necessary and appropriate to accomplishment of the work.\2\
---------------------------------------------------------------------------

    \2\ If there is a need, these contracts may be written for 5 years 
also but funded only as outlined in paragraph 4(a) of this Appendix.
---------------------------------------------------------------------------

    (b) Limitations on Personal Services Contracts. (1) Personal 
services contracts may only be used when adequate supervision is 
available.
    (2) Personal services contracts may be used for commercial 
activities. Commercial activities provide a product or service which 
could be obtained from a commercial source. See Attachment A of OMB 
Circular A-76 for a representative list of such activities.
    (3) Notwithstanding any other provision of USAID directives, 
regulations or delegations, U.S. citizen personal services contractors 
(USPSCs) may be delegated or assigned any authority, duty or 
responsibility delegable to U.S. citizen direct-hire employees (USDH 
employees) except that:
    a. They may not supervise U.S. direct-hire employees of USAID or 
other U.S. Government agencies. They may supervise USPSCs and non-U.S. 
citizen employees.
    b. They may not be designated as Contracting Officers or delegated 
authority to sign obligating or subobligating documents.
    c. They may represent the agency, except that communications that 
reflect a final policy, planning or budget decision of the agency must 
be cleared by a USDH employee.
    d. They may participate in personnel selection matters, but may not 
be delegated authority to make a final decision on personnel selection.
    e. Exceptions to the limitations in this paragraph (b)(3) must be 
approved by the Assistant Administrator for Management (AA/M).
    (c) Withholdings and Fringe Benefits. (1) Personal services 
contractors (PSCs) are Government employees for purposes of the Internal 
Revenue Code (Title 26 of the United States Code) and are, therefore, 
subject to social security (FICA) and Federal income tax (FIT) 
withholdings. As employees, they are ineligible for the ``foreign earned 
income'' exclusion under the Internal Revenue Service (IRS) regulations 
(see 26 CFR 1.911-3(c)(3)).
    (2) Personal services contractors are treated on par with other 
Government employees, except for programs based on any law administered 
by the Federal Office of Personnel Management (e.g., incentive awards, 
life insurance, health insurance, and retirement programs covered by 5 
CFR Parts 530, 531, 831, 870, 871, and 890). While PSCs are ineligible 
to participate in any of these programs, the following fringe benefits 
are provided as a matter of policy:
    (i) The employer's FICA contribution for retirement purposes.
    (ii) A contribution against the actual cost of the PSC's annual 
health and life insurance costs. Proof of health and life insurance 
coverage and its actual cost to the PSC shall be submitted to the 
Contracting Officer before any contribution is made. (See also paragraph 
4(c)(3) of this Appendix.)
    (A) The contribution for health insurance shall not exceed 50% of 
the actual cost to the PSC for his/her annual health insurance, or the 
maximum U.S. Government contribution for a direct-hire employee, as 
announced annually by the Office of Personnel Management, whichever is 
less. If the PSC is covered under a spouse's health insurance plan, 
where the spouse's employer pays some or all of the health insurance 
costs, the cost to the PSC for annual health insurance shall be 
considered to be zero.
    (B) The contribution for life insurance shall be up to 50% of the 
actual annual costs to the PSC for life insurance, not to exceed $500.00 
per year.
    (iii) PSCs shall receive the same percentage pay comparability 
adjustment as U.S. Government employees subject to the availability of 
funds.
    (iv) PSCs shall receive a 3% annual salary increase subject to 
satisfactory performance documented in their annual written evaluation. 
Such increase may not exceed 3% without a deviation. This 3% limitation 
also applies to extensions of the same service or negotiations for a new 
contract for the same or similar services unless a deviation has been 
approved.
    (v) PSCs shall receive the following allowances and differentials 
provided in the State Department's Standardized Regulations (Government 
Civilians Foreign Areas) on the same basis as U.S. Government employees 
(except for U.S. resident hires, see paragraph 4(d) and Section 12, 
General Provisions, Clause 22, ``U.S. Resident Hire Personal Services 
Contractors''):
    (A) Temporary lodging allowance (Section 120),\3\
---------------------------------------------------------------------------

    \3\ Mission Directors may authorize per diem in lieu of these 
allowances.
---------------------------------------------------------------------------

    (B) Living quarters allowance (Section 130),\3\
    (C) Post allowance (Section 220),\3\
    (D) Supplemental post allowance (Section 230),\3\
    (E) Separate maintenance allowance (Section 260),\4\
---------------------------------------------------------------------------

    \4\ These allowances are not authorized for short tours (i.e., less 
than a year).
---------------------------------------------------------------------------

    (F) Education allowance (Section 270),\4\
    (G) Educational travel (Section 280),\4\
    (H) Post differential (Section 500),
    (I) Payments during evacuation/authorized departure (Section 600), 
and

[[Page 88]]

    (J) Danger pay (Section 650).
    (vi) Any allowance or differential that is not expressly stated in 
paragraph 4(c)(2)(v) is not authorized for any PSC unless a deviation is 
approved. The only exception is a consumables allowance if authorized 
for the post under Handbook 22 or superseding ADS Chapter.
    (vii) Health room services may be provided in accordance with the 
clause of this contract entitled ``Physical Fitness and Health Room 
Privileges.''
    (viii) PSCs are eligible to receive benefits for injury, disability, 
or death under the Federal Employees' Compensation Act since the law is 
administered by the Department of Labor not the Office of Personnel 
Management.
    (ix) PSCs are eligible to earn four hours of annual leave and four 
hours of sick leave for each two week period. However, PSCs with 
previous PSC service (not previous U.S. Government civilian or military 
service) earn either six hours of annual leave for each two week period 
if their previous PSC service exceeds 3 years (including 10 hours annual 
leave for the final pay period of a calendar year), or eight hours of 
annual leave for each two week period if their previous PSC service 
exceeds 15 years.
    (3) A PSC who is a spouse of a current or retired Civil Service, 
Foreign Service, or Military Service member and who is covered by their 
spouse's Government health or life insurance policy is ineligible for 
the contribution under paragraph 4(c)(2)(ii) of this appendix.
    (4) Retired U.S. Government employees shall not be paid additional 
contributions for health or life insurance under their contract (since 
the Government will normally have already paid its contribution for the 
retiree) unless the employee can prove to the satisfaction of the 
Contracting Officer that his/her health and life insurance does not 
provide or specifically excludes coverage overseas. If coverage overseas 
is excluded, then eligibility as cited in paragraph 4(c)(3) applies.
    (5) Retired U.S. Government employees may be awarded Personal 
Services Contracts without any reduction in or offset against their 
Government annuity.
    (d) U.S. Resident Hire Personal Services Contractors. U.S. resident-
hire PSCs are not eligible for any fringe benefits (except contributions 
for FICA, health insurance, and life insurance), including differentials 
and allowances unless such individuals can demonstrate to the 
satisfaction of the Contracting Officer that they have received similar 
benefits and allowances from their immediately previous employer in the 
cooperating country, or the Mission Director may determine that payment 
of such benefits would be consistent with the Mission's policy and 
practice and would be in the best interests of the U.S. Government.
    (e) Determining Salary for Personal Services Contractors. (1) There 
are two separate and distinct methods of establishing a salary for 
personal services contractors. Use of method number 1 is required unless 
justified and approved as provided for in paragraph (e)(1)(ii).
    (i) Method 1: Salaries for Personal Services Contractors shall be 
established based on the market value in the United States of the 
position being recruited for. This requires the Contracting Officer in 
coordination with the Technical Officer to determine the correct market 
value (a salary range) of the position to be filled. This method is 
required in establishing salary for all PSCs unless method 2 is 
authorized as provided for in paragraph (e)(1)(ii). Contract Information 
Bulletin (CIB) 96-8 dated February 23, 1996 provides a guide which 
contains information concerning Preparation of Scopes of Work, 
Determination of Salary Class Grade, Salary Class Bench Marks and Salary 
Class Review. The market value of the position then becomes the basis 
along with the applicants' certified salary history on the SF 171, 
``Personal Qualifications Statement'' for salary negotiations by the 
Contracting Officer. The SF 171 must be retained in the permanent 
contract file. Any position which is determined to be above the GS-13 
equivalent and exceeds six months in duration must be classified by M/
HR/POD. The crucial point is the establishment of a realistic and 
reasonable market value for a job. The final determination regarding the 
reasonableness of a salary level rests with the Contracting Officer. 
Paying salaries using this method avoids ``rank in person'' salaries 
which are in excess of the value of the job being contracted for.
    (ii) Method 2: If approved in writing by the Mission Director or the 
cognizant Assistant Administrator, based on written justification, 
salary may be negotiated based on the applicant's current earnings 
adjusted in accordance with the factors set out in paragraphs (e)(1)(ii) 
(A) through (C). This approval requirement cannot be redelegated. 
Current earnings must be certified by the contractor on the SF 171, (see 
paragraph 6(b)(3) of this appendix). This is guidance for establishing 
initial salaries, not subsequent increases, for the same contractor 
performing the same function.
    (A) As a rule, up to a 3 percent increase above current earnings may 
be given. However, a 3 percent increase is awarded only to a PSC whose 
earnings are based on a period of twelve months or more; 2 percent for 
established earnings of less than twelve months but not less than four 
months; or 1 percent for established earnings during the past four 
months.
    (B) Additional percentages may be given for the following factors. 
If a PSC has worked in a developing country for more

[[Page 89]]

than two years, an additional 1 percent may be awarded. Education 
related to the area of specialization and above the minimum 
qualification required may warrant an additional 1 percent, and those 
specialties for which there is keen competition in the employment market 
or a serious shortage category nationwide may be awarded an additional 2 
percent. In addition, related technical experience over 5 years may 
increase the percentage by 1 and over ten years by 3.
    (C) All requests for an initial rate of pay above 10 percent over 
current earnings must be approved in writing by the appropriate 
Assistant Administrator or Mission Director. Current earnings are actual 
earnings for work reasonably related to the position for which the 
applicant is being considered. Paragraphs 4(e)(1)(ii) (A) through (C) 
apply only to salary setting method number 2 in paragraph 4 (e)(1)(ii).
    (2) When an applicant has no current earnings history (e.g., a 
person returning to the workforce after an absence of a number of years) 
or when an applicant's current earnings history doesn't accurately 
reflect the applicant's job market worth (e.g., a Peace Corps 
volunteer), every effort should be made to establish a market value for 
the position as a basis for negotiation, notwithstanding the lack of a 
current earnings history, provided that the applicant has the full 
qualifications for the job and could command a similar salary in the 
open job market.
    (3) Salaries in excess of the ES-6 level must also be approved by 
the Procurement Executive based upon a memorandum through the 
appropriate Assistant Administrator or Mission Director and Contracting 
Officer, as provided for in internal guidelines on ``Approval Procedures 
for Contractor Salaries''. This approval level cannot be redelegated.
    (f) Incentive Awards. U.S. PSCs are not eligible to receive monetary 
awards. They are eligible for non-monetary awards such as certificates.
    (g) Annual Salary Increase. PSC contracts written for more than one 
year should provide for a 3% annual increase based on satisfactory 
performance documented in their annual written evaluations.
    (h) Pay Comparability Adjustment. PSCs shall receive the same 
percentage pay comparability adjustment as that received by U.S. 
Government employees subject to the availability of funds.
    (i) Subcontracting. PSCs are U.S. Government employees and may not 
be called upon (or permitted) to subcontract out any part of their work. 
Funds for subcontracting have no place in the budget of a personal 
services contract. Support services, equipment, and supplies (e.g., 
typing and report preparation, paper, pens, computers, and furniture) 
should be furnished to PSCs just as they would be to direct-hire 
employees. To the extent that direct-hire personnel may be authorized to 
purchase supporting services or supplies under a travel authorization, 
so may PSCs; otherwise, contracts for personal services should not 
contain any funds for procurement.

    5. Soliciting for Personal Services Contracts. (a) Technical 
Officer's Responsibilities. The Technical Officer will prepare a written 
detailed statement of duties and a statement of minimum qualifications 
to cover the position being recruited for. The statement shall be 
included in the procurement request (the Acquisition & Assistance 
Request Document) e.g., the request shall also include the following 
additional information as a minimum:
    (1) The specific foreign location(s) where the work is to be 
performed, including any travel requirements (with an estimate of 
frequency);
    (2) The length of the contract, with beginning and ending dates, 
plus any options for renewal or extension;
    (3) The basic education, training, experience, and skills required 
for the position;
    (4) An estimate of what a comparable GS/FS equivalent position 
should cost, including basic salary, allowances, and differentials, if 
appropriate; and
    (5) A list of Government or host country furnished items (e.g., 
housing).
    (b) Contracting Officer's Responsibilities. (1) The Contracting 
Officer will prepare the solicitation for personal services which shall 
contain:
    (i) Three sets of SF 171s and SF 171As. (Upon receipt, one copy of 
each SF 171 and SF 171A shall be forwarded to the Project Officer.)
    (ii) A detailed statement of duties or a completed position 
description for the position being recruited for.
    (iii) A copy of the prescribed contract Cover Page, Contract 
Schedule, General Provisions as appropriate, as well as the FAR Clauses 
to be incorporated in full text and by reference.
    (iv) A copy of the USAID General Notice entitled ``Employee Review 
of the New Standards of Conduct''.
    (2) The Contracting Officer shall comply with the requirements of 
(48 CFR) AIDAR 706.302-70(c) as detailed in paragraph 5(c) except those 
recruited from the U.S.
    (c) Competition. (1) Under (48 CFR) AIDAR 706.302-70(b)(1), Personal 
Services Contracts (except those recruited from the U.S.) are exempt 
from the requirements for full and open competition with two limitations 
that must be observed by Contracting Officers:
    (i) Offers are to be requested from as many potential offerors as is 
practicable under the circumstances, and

[[Page 90]]

    (ii) A justification supporting less than full and open competition 
must be prepared in accordance with FAR 6.303.
    (2) PSCs With Untied States Citizens or Resident Aliens Recruited 
from Outside the Cooperating Country. Solicitations for PSCs recruited 
outside the cooperating country must be publicized via the Agency's 
External Home Page on the Internet under the caption ``Business & 
Procurement, USAID Procurements.'' Instructions regarding how to access 
the External Internet and the information to be provided have been 
approved and included in a CIB. A justification under FAR 6.303 is not 
required when this procedure is followed.
    (3) A class justification was approved by the USAID Procurement 
Executive to satisfy the requirements of (48 CFR) AIDAR 706.302-70(c)(2) 
for a justification in accordance with FAR 6.303. This class 
justification for Personal Services Contracts with U.S. Citizens may 
only be used for those who are recruited locally subject to the 
following conditions:
    (i) The position was publicized locally in accordance with 
established Mission policy or procedure, or the procedures in paragraph 
5(c)(ii) was followed;
    (ii) As an alternative to the procedures in paragraphs 5(c) (i) and 
(ii), at least 3 individuals were considered by consulting source lists 
(e.g., applications or resumes on hand) or conducting other informal 
solicitation.
    (iii) Extensions or renewals with the same individual for continuing 
services do not need to be publicized.
    (iv) A copy of the class justification (which was distributed to all 
USAID Contracting Officers via Contract Information Bulletin) must be 
included in the contract file, together with a written statement, signed 
by the Contracting Officer, that the contract is being awarded pursuant 
to (48 CFR) AIDAR 706.302-70(b)(1); that the conditions for use of this 
class justification have been met; and that the cost of the contract is 
fair and reasonable.
    (4) If the appropriate competitive procedure in paragraph 5(3) is 
not followed, the Contracting Officer must prepare a separate 
justification as required under (48 CFR) AIDAR 706.302-70(c)(2).
    (5) Since the award of a Personal Services Contract is based on 
technical qualifications, not price, and since the SF 171, ``Personal 
Qualifications Statement'', and SF 171A, ``Continuation Sheet for 
Standard Form 171'', are used to solicit for such contracts, FAR 
subparts 15.4 and 15.5 and FAR parts 52 and 53 are inappropriate and 
shall not be used. Instead, the solicitation and selection procedures 
outlined in this Appendix shall govern.

    6. Negotiating a Personal Services Contract. Negotiating a Personal 
Services Contract is significantly different from negotiating a 
nonpersonal services contract because it establishes an employer-
employee relationship; therefore, the selection procedures are more akin 
to the personnel selection procedures.
    (a) Technical Officer's Responsibilities. The Technical Officer 
shall be responsible for reviewing and evaluating the applications 
(i.e., SF 171s) received in response to the solicitation issued by the 
Contracting Officer. If deemed appropriate, interviews may be conducted 
with the applicants before the final selection is submitted to the 
Contracting Officer.
    (b) Contracting Officer's Responsibilities. (1) The Contracting 
Officer shall forward a copy of each SF 171 received under the 
solicitation to the Project Officer for evaluation.
    (2) On receipt of the Technical Officer's recommendation, the 
Contracting Officer shall conduct negotiations with the recommended 
applicant. Normally, the Contracting Officer shall negotiate only the 
salary (see the salary setting coverage in paragraph 4(e) of this 
Appendix). The terms and conditions of the contract, including 
differentials and allowances, are not negotiable or waivable without a 
properly approved deviation (see (48 CFR) AIDAR 701.470). If the 
Contracting Officer can negotiate a salary that is fair and reasonable, 
then the award shall be made.
    (3) The Contracting Officer shall use the certified salary history 
on the SF 171 as the basis for salary negotiations, along with the 
market value of the position being recruited for (unless approval not to 
use market value has been granted under paragraph 4(e)(1)(ii)), and the 
Technical Officer's cost estimate.
    (4) The Contracting Officer will obtain two copies of IRS Form W-4, 
``Employee's Withholding Allowance Certificate'', from the successful 
applicant. (Upon receipt, the Contracting Officer will forward one copy 
of the W-4 to the Office of the Controller.)
    (5) Security clearance is required for all U.S. citizens entering 
into USAID PSCs. The Contracting Officer will obtain four sets of SF 86, 
``Security Investigation Data for Sensitive Position'', from the 
successful applicant and forward them to the Office of Security. PSCs 
may receive a preliminary clearance and be placed under contract prior 
to receipt of clearance provided the appropriate paper work has been 
completed, reviewed by IG/SEC/PSI and acknowledged as a ``no objection'' 
to the appropriate Mission. See General Provision 24 in section 12 of 
this Appendix.

    7. Executing a Personal Services Contract. Contracting Officers or 
Heads of Contracting Activities, whether USAID/W or Mission, may execute 
Personal Services Contracts, provided that the amount of the contract 
does not exceed the contracting authority that has been redelegated to 
them. In executing a Personal Services Contract, the

[[Page 91]]

Contracting Officer is responsible for insuring that:
    (a) The proposed contract is within his/her delegated authority;
    (b) A Request Number covering the proposed contract has been 
received;
    (c) The position has been classified by either the Mission or M/HR/
POD (see CIB 96-8) and the classification is in the contract file;
    (d) The proposed Statement of Duties is contractible, contains a 
statement of minimum qualifications from the technical office requesting 
the services, and is suitable to the use of a Personal Services Contract 
in that:
    (1) Performance of the proposed work requires or is best suited for 
an employer-employee relationship, and is thus not suited to the use of 
a non-personal services contract;
    (2) The Statement of Duties does not require performance of any 
function normally reserved for Federal employees (see paragraph 4(b) of 
this Appendix); and
    (3) There is no apparent conflict of interest involved (if the 
Contracting Officer believes that a conflict of interest may exist, the 
question should be referred to the cognizant legal counsel);
    (e) Selection of the contractor is documented and justified. (48 
CFR) AIDAR 706.302-70(b)(1) provides an exception to the requirement for 
full and open competition for Personal Services Contracts abroad (see 
paragraph 5(c) of this Appendix);
    (f) The standard contract format prescribed for Personal Services 
Contracts (Sections 10, 11, 12 and 13 to this Appendix) is used; or that 
any necessary deviations are processed as required by (48 CFR) AIDAR 
701.470.

    (Note: The prescribed contract format is designed for use with 
contractors who are residing in the U.S. when hired. If the contract is 
with a U.S. citizen residing in the cooperating country when hired, 
contract provisions governing physical fitness and travel/transportation 
expenses, and home leave, allowances, and orientation should be suitably 
modified (see paragraph 4(d) of this Appendix)).

These modifications are not considered deviations subject to (48 CFR) 
AIDAR 701.470. (Justification and explanation of these modifications is 
to be included in the contract file);
    (g) Orientation is arranged in accordance with General Provision 23 
in section 12 of this Appendix;
    (h) The contractor has submitted the names, addresses, and telephone 
numbers of at least two persons who may be notified in the event of an 
emergency (this information is to be retained in the contract file);
    (i) The contract is complete and correct and all information 
required on the contract Cover Page (USAID Form 1420-36A) has been 
entered;
    (j) The contract has been signed by the Contracting Office and the 
contractor, and fully executed copies are properly distributed;
    (k) The following clearances, approvals and forms have been 
obtained, properly completed, and placed in the contract file before the 
contract is signed by both parties;
    (1) Evidence of job classification in the file by the Mission except 
for grade equivalents above GS-13. For those positions with grade 
equivalent above GS-13, evidence of job classification done by M/HR/POD;
    (2) Security clearance, including the completed SF 86, to the extent 
required by USAID Handbook 6, Security or superseding ADS Chapter, (see 
General Provisions 14 and 24 in section 12 of this Appendix);
    (3) Mission, host country, Human Resources Office, and technical 
office clearance, as appropriate;
    (4) Medical examinations and certifications as required by the 
contract general provision entitled ``Physical Fitness and Health Room 
Privileges'';
    (5) One original executed IRS Form W-4 entitled ``Employee's 
Withholding Allowance Certificate'', and one copy, shall be obtained. 
The original shall be sent to the Controller of the paying office and 
one shall be placed in the contract file;
    (6) Evidence of DAA/HR clearance that the position may be filled by 
PSC.
    (7) The approval for any salary in excess of ES-6, in accordance 
with Appendix G of this chapter;
    (8) A copy of the class justification or other appropriate 
explanation and support required by (48 CFR) AIDAR 706.302-70, if 
applicable;
    (9) Any deviation to the policy or procedures of this appendix, 
processed and approved under (48 CFR) AIDAR 701.470;
    (10) A fully executed SF 171, and a copy of the position 
classification, and approved deviation, if appropriate;
    (11) The Memorandum of Negotiation; and
    (12) The Contracting Officer's signed certification that competition 
requirements have been satisfied as described in paragraph 5(c) of the 
policy text of this Appendix. The certification shall be a part of the 
Memorandum of Negotiations.
    (l) Funds for the contract are properly obligated to preclude 
violation of the Anti-Deficiency Act, 31 U.S.C. 1341 (the Contracting 
Officer ensures that the contract has been properly recorded by the 
appropriate accounting office prior to its release for the signature of 
the selected contractor);
    (m) The contractor receives and understands the USAID General Notice 
entitled ``Employee Review of the New Standards of

[[Page 92]]

Conduct'' and a copy is attached to each contract as provided for in 
paragraph (c) of General Provision 1, section 12;
    (n) Agency conflict of interest requirements as set out in the 
General Notice ``Employee Review of the New Standards of Conduct'' are 
met by the contractor prior to his/her reporting for duty;
    (o) A copy of a Checklist for Personal Services contractors which 
may be in the format set out in this section or another format 
convenient for the Contracting Officer, provided that a memorandum 
containing all of the information described in this section 7 shall be 
prepared for each PSC and placed in the contract file;
    (p) The contractor understands that he/she is an employee of the 
United States for purposes of the Foreign Assistance Act of 1961, as 
amended, and the Internal Revenue Code (Title 26 of the United States 
Code). This subjects the employee to withholding for both FICA and 
Federal Income Tax and precludes the employee from receiving the Federal 
Earned Income Tax exclusion of 26 U.S.C. Section 911. See Special Note 
on the Cover Page of USAID Form 1420-36.
    (q) The contractor also understands that he/she may commence work 
prior to the completion of the security clearance. However, until such 
time as clearance is received, the contractor may not have access to 
classified or administratively controlled materials. Failure to obtain 
clearances will constitute cause for termination.

    8. Post Audit. The Inspector General, or his/her designee, audits 
the Personal Services Contracts of all contracting activities for the 
purpose of ensuring conformance to applicable policy and regulations.

    9. Contracting Format. The prescribed Contract Cover Page, Contract 
Schedule, General Provisions, and appropriate Federal Acquisition 
Regulations (FAR) clauses for Personal Services Contracts covered by 
this appendix are included as follows:
    10. Form USAID 1420-36, ``Cover Page'' and ``Schedule''.
    11. Optional Schedule With a U.S. Citizen or U.S. Resident Alien.
    12. General Provisions.
    13. FAR Clauses to be Incorporated in Full Text in Personal Services 
Contracts.
    14. FAR Clauses to be incorporated by reference in Personal Services 
Contracts.

    10. Form USAID 1420-36, ``Cover Page'' and ``Schedule''.

    Contract With a U.S. Citizen or U.S. Resident Alien for Personal 
         Services Abroad--Form AID 1420-36A (11/96) (Cover Page)

[[Page 93]]

[GRAPHIC] [TIFF OMITTED] TR23JY97.000



                          PRIVACY ACT STATEMENT

    This information is provided pursuant to Public Law 93-579 (Privacy 
Act of 1974), December 31, 1974, for individuals who complete this form.
    The Executive Office of the President, Office of Management and 
Budget has required

[[Page 94]]

that all departments and agencies comply with the reporting requirements 
of Section 6041 of the Internal Revenue Code, Section 6041 states that 
all departments and agencies making payments totalling $600 or more in 
one year to a recipient for services provided must be reported to the 
Internal Revenue Service (IRS). The SSN and all financial numbers will 
be disclosed to U.S. Agency for International Development (USAID) 
payroll office personnel and personnel in the Department of the 
Treasury, Division of Disbursements. USAID will use this SSN to complete 
Form W-2 of the Code on employee compensation. Disclosure by the 
personal services contractor of the SSN is necessary to obtain the 
services, benefits or processes provided by this contract. Disclosure of 
the SSN may be made outside USAID (a) pursuant to any applicable routine 
use listed in USAID's Notice for implementing the Privacy Act as 
published in the Federal Register or (b) when disclosure by virtue of a 
contract being a public document after signatures is authorized under 
the Freedom of Information Act.

                                Schedule

    (The Illustrated Schedule consists of this Table of Contents--
Articles I-VI, and the General Provisions.)

                            TABLE OF CONTENTS

Article I--Statement of Duties
Article II--Period of Service Overseas
Article III--Contractor's Compensation and Reimbursement in U.S. Dollars
Article IV--Costs Reimbursable and Logistic Support
Article V--Precontract Expenses
Article VI--Additional Clauses

    General Provisions:
    The following provisions numbered as shown below omitting number(s) 
______, are the General Provisions (GPs) of this Contract:

1. Definitions
2. Laws and Regulations Applicable Abroad
3. Physical Fitness and Health Room Privileges
4. Workweek and Compensation (Pay Comparability Adjustments)
5. Leave and Holidays
6. Differential and Allowances
7. Social Security, Federal Income Tax and Foreign Earned Income
8. Advance of Dollar Funds
9. Insurance
10. Travel and Transportation Expenses
11. Payment
12. Conversion of U.S. Dollars to Local Currency
13. Post of Assignment Privileges
14. Security Requirements
15. Contractor-Mission Relationships
16. Termination
17. Release of Information
18. Notices
19. Reports
20. Use of Pouch Facilities
21. Biographical Data
22. Resident Hire PSC
23. Orientation and Language Training
24. Conditions for Contracting Prior to Receipt of Security Clearance
25. Medical Evacuation Services
26. Governing Law

    For each tour of duty, attach the applicable General Provisions.
    Schedule: (Note: Use of the following Schedule Articles are not 
mandatory. They are intended to serve as guidelines for contracting 
offices in drafting contract schedules. Article language may be changed 
to suit the needs of the particular contract).

                     Article I--Statement of Duties

    (The statement of duties shall include:
    A. General statement of the purpose of the contract.
    B. Statement of duties to be performed.
    C. Any USAID consultation or orientation.)

                 Article II--Period of Service Overseas

    Within ______ days after written notice from the Contracting Officer 
that all clearances, including the doctor's statement of medical opinion 
required under General Provision Clause 4, have been received or unless 
another date is specified by the Contracting Officer in writing, the 
contractor shall proceed to ______ where he/she shall promptly commence 
performance of the duties specified above. The contractor's period of 
service overseas shall be approximately ______ in ______. (Specify time 
of duties in each location as well as authorized stopovers with purpose 
of each.)

Article III--Contractor's Compensation and Reimbursement in U.S. Dollars

    A. Except to the extent reimbursement is payable in the currency of 
the Cooperating Country pursuant to Article IV, USAID shall pay the 
contractor compensation after it has accrued and reimburse him/her in 
U.S. dollars for necessary and reasonable costs actually incurred by 
him/her in the performance of this contract within the categories listed 
in paragraph C, below, and subject to the conditions and limitations 
applicable thereto as set out herein and in the attached General 
Provisions (GP).
    B. The amount budgeted and available as personal compensation to the 
contractor is calculated to cover a calendar period of approximately 
______ (days) (weeks) (months) (years) which is to include:
    (1) vacation, sick, and home leave which may be earned during the 
contractor's tour of duty (GP Clause 5);

[[Page 95]]

    (2) ______ days for authorized travel (GP Clause 10); and
    (3) ______ days for orientation and consultation in the United 
States (GP Clause 23).
    C. Allowable Costs: 1. Compensation at the rate of $______ per 
(year) (month) (week) (day). Adjustments in compensation (pay) for 
periods when the contractor is not in compensable pay status shall be 
calculated as follows:
    Rate of $______ per (day) (hour).
    Contingency for Compensation (Pay Comparability) Adjustments. 
$______.
    Annual Salary increase (3%) $______.
    2. Overtime (Unless specifically authorized in the Schedule of this 
contract, no overtime hours shall be allowed hereunder.) $______.
    * 3. Overseas Differential (Ref. GP Clause No. 6.) Rate $______ and 
Contingency $______=Total $______.
---------------------------------------------------------------------------

    * If post differential is applicable to the assigned post, a 
contingency for the adjusted amount of differential resulting from 
compensation (pay comparability) adjustment should be included.
---------------------------------------------------------------------------

    ** 4. Allowances in Cooperating Country (Ref. GP Clause 6.) $______.
---------------------------------------------------------------------------

    ** Do not include the value of any costs to be paid or reimbursed in 
local currency.
---------------------------------------------------------------------------

    ** 5. Travel and Transportation (Ref. GP Clause 10.) (Includes the 
value of GTRs furnished by the Government, not payable to contractor). 
$______.
    a. United States  $______
    b. International  $______
    c. Cooperating and Third Country  $______
    Subtotal Item 5  $______
    ** 6. Subsistence or Per Diem (Ref. GP Clause 10.)
    a. Untied States  $______
    b. International  $______
    c. Cooperating and Third Country  $______.
    Subtotal Item 6  $______
    7. Other Direct Costs.
    a. Health and Life Insturance  $______
    b. Precontract Costs, passport, visa, inoculations, etc. (Ref. GP 
Clause 8.) $______
    c. Physical Examination (Ref. GP Clause 3.)  $______
    d. Communications, Miscellaneous.  $______
    Subtotal Item 7  $______
    8. F.I.C.A.-U.S.G. Contribution (not payable to contractor).  
$______
    D. Maximum U.S.-Dollar Obligation:
    In no event shall the maximum U.S.-dollar obligation under this 
contract exceed $______. Contractor shall keep a close account of all 
obligations he/she incurs and accrues hereunder and promptly notify the 
Contracting Officer whenever in his/her opinion the said maximum is not 
sufficient to cover all compensation and costs reimbursable in U.S. 
dollars which he/she anticipates under the contract.

           Article IV--Costs Reimbursable and Logistic Support

    A. General: The contractor shall be provided with or reimbursed in 
local currency (______) for the following:

                               [Complete]

    B. Method of Payment of Local Currency Costs: Those contract costs 
which are specified as local currency costs in paragraph A above, if not 
furnished in kind by the cooperating government or the Mission, shall be 
paid to the contractor in a manner adapted to the local situation, based 
on vouchers submitted in accordance with General Provision Clause 11. 
The documentation for such costs shall be on such forms and in such 
manner as the Mission Director shall prescribe.

                               [Complete]

                     Article V--Precontract Expenses

    No expense incurred before execution of this contract will be 
reimbursed unless such expense was incurred after receipt and acceptance 
of a precontract expense letter issued to the contractor by the 
Contracting Officer, and then only in accordance with the provisions and 
limitations contained in such letter. The rights and obligations created 
by such letter shall be considered as merged into this contract.

                     Article VI--Additional Clauses

    (Additional Schedule Clauses may be added such as the implementation 
of General Provisions or Additional Clauses.)

    11.Optional Schedule With a U.S. Citizen or U.S. Resident Alien

     A U.S. Citizen or a U.S. Resident Alien PSC Contract No. ______

                            TABLE OF CONTENTS

                           (Optional Schedule)

    (Use of the Optional Schedule is not mandatory. It is intended to 
serve as an alternate procedure for OE funded U.S. PSCs or U.S. Resident 
Alien PSCs. The Schedule is for use when the Contracting Officer 
anticipates incremental recurring cost funded contracts.
    Use of the Optional Schedule eliminates the need to amend the 
contract each time funds are obligated. However, the Contracting Officer 
is required to amend each contract not less than twice during a 12 month 
period to ensure that the contract record of obligations is up to date 
and agrees with the figures in the master funding document.)
    The Schedule on pages ______ thru ______ consists of this Table of 
Contents and the following Articles:

Article I--Statement of Duties
Article II--Period of Service Overseas

[[Page 96]]

Article III--Contractor's Compensation and Reimbursement in U.S. Dollars
Article IV--Costs Reimbursable and Logistic Support
Article V--Precontract Expenses
Article VI--Additional Clauses

    General Provisions:
    The following provisions, numbered as shown below, omitting 
number(s) ______, are the General Provisions (GP) of this Contract:

1. Definitions
2. Laws and Regulations Applicable Abroad
3. Physical Fitness and Health Room Privileges
4. Workweek and Compensation (Pay Comparability Adjustments)
5. Leave and Holidays
6. Differential and Allowances
7. Social Security and Federal Income Tax
8. Advance of Dollar Funds
9. Insurance
10. Travel and Transportation Expenses
11. Payment
12. Conversion of U.S. Dollars of Local Currency
13. Post of Assignment Privileges
14. Security Requirements
15. Contractor-Mission Relationships
16. Termination
17. Release of Information
18. Notices
19. Reports
20. Use of Pouch Facilities
21. Biographical Data
22. Resident Hire PSC
23. Orientation and Language Training
24. Conditions for Contracting Prior to Receipt of Security Clearance
25. Medical Evacuation Services
26. Governing Law

    For each tour of duty, attach the applicable General Provisions.

                     Article I--Statement of Duties.

    (The statement of duties shall include:
    A. General statement of the purpose of the contract.
    B. Statement of duties to be performed.
    C. Any USAID consultation or orientation.)

                 Article II--Period of Service Overseas.

    Within ______ days after written notice form the Contracting Officer 
that all clearances, including the doctor's statement of medical opinion 
required under General Provision Clause 3, have been received or unless 
another date is specified by the Contracting Officer in writing, the 
contractor shall proceed to ______ where he/she shall promptly commence 
performance of the duties specified above. The contractor's period of 
service overseas shall be approximately ______ in ______. (Specify time 
of duties in each location as well as authorized stopovers with purpose 
of each.)

    Article III--Contractor's Compensation and Reimbursement in U.S. 
                                Dollars.

    A. Except to the extent reimbursement is payable in the currency of 
the Cooperating Country pursuant to Article IV, USAID shall pay the 
contractor compensation after it has accrued and reimburse him/her in 
U.S. dollars for necessary and reasonable costs actually incurred by 
him/her in the performance of this contract within the categories listed 
in paragraph C, below, and subject to the conditions and limitations 
applicable thereto as set out herein and in the attached General 
Provisions (GP).
    B. The amount budgeted and available as personal compensation to the 
contractor is calculated to cover a calendar period of approximately 
______ (days) (weeks) (months) (years) which is to include:
    1. Vacation, sick, and home leave which may be earned during the 
contractor's tour of duty (GP Clause 5);
    2. ______ days for authorized travel (GP Clause 10); and
    3. ______ days for orientation and consultation in the United States 
(GP Clause 23).
    C. Allowable Costs: 1. The following illustrative budget details 
allowable costs under this contract and provides estimated incremental 
recurrent cost funding in the total amount shown. Additional funds for 
the full term of this contract will be provided by the preparation of a 
master PSC funding document issued by the Mission Controller for the 
purpose of providing additional funding for a specific period. The 
master PSC funding document will be attached to this contract and will 
form a part of the executed contract while also serving to amend the 
budget.
    2. Compensation at the rate of $______ per (year) (month) (week) 
(day). Adjustments in compensation (pay) for periods when the contractor 
is not in compensable pay status shall be calculated as follows:
    Rate of $______ per (day) (hour).
    Contingency for Compensation (Pay Comparability Adjustments.) 
$______
    Annual Salary increase (3%) $______
    3. Overtime (Unless specifically authorized in the Schedule of this 
contract, no overtime hours shall be allowed hereunder.) $______
    * 4. Overseas Differential (Ref. GP Clause No. 6.) Rate $______ and 
Contingency $______ = Total $______.
    ** 5. Allowances in Cooperating Country (Ref. GP Clause 6.) $______
---------------------------------------------------------------------------

    * If post differential is applicable to the assigned post, a 
contingency for the adjusted amount of differential resulting from 
compensation (pay comparability) adjustment should be included.

---------------------------------------------------------------------------

[[Page 97]]

    ** 6. Travel and Transportation (Ref. GP Clause 10.) (Includes the 
value of GTRs furnished by the Government, not payable to contractor). 
$______.
---------------------------------------------------------------------------

    ** Do not include the value of any costs to be paid or reimbursed in 
local currency.
---------------------------------------------------------------------------

    a. United States  $______
    b. International  $______
    c. Cooperating and Third Country  $______
    Subtotal Item 6  $______
    **7. Subsistence or Per Diem (Ref. GP Clause 10.)
    a. United States  $______
    b. International  $______
    c. Cooperating and Third Country  $______
    Subtotal Item 7  $______
    **8. Other Direct Costs
    a. Health and Life Insurance (Ref. GP Clause 9.)  $______
    b. Precontract Costs, passport, visa, inoculations, etc. (Ref. GP 
Clause 8.)  $______
    c. Physical Examination (Ref. GP Clause 3.)  $______
    d. Communications, Miscellaneous Subtotal Item 8  $______
    9. F.I.C.A.--U.S.G. contribution (not payable to contractor).  
$______
    D. Maximum U.S.-Dollar Obligation: In no event shall the maximum 
U.S.-dollar obligation under this contract exceed $______.
    E. Salary changes and personnel-related contract actions will be 
made by processing the same forms as used in making such changes and 
actions for direct-hire employees. When issued by the Contracting 
Officer, the forms utilized will be attached to the contract and will 
form a part of the contract terms and conditions.
    F. Any adjustment or increase in the compensation granted to direct-
hire employees will be allowed for in PSCs subject to the availability 
of funds. Such an adjustment will be effected by a mass pay adjustment 
notice from the Contracting Officer, which will be attached to the 
contract and form a part of the executed contract.
    G. At the end of each year of satisfactory service, PSC contractors 
will be eligible to receive an increase equal to 3% pending availability 
of funds provided their services have been satisfactory. Such increase 
will be effected by the execution of an SF-1126, payroll change slip 
which is to be attached to each contract and each action forms a part of 
the official contract file.
    H. The master PSC funding document may not exceed the term or 
estimated total cost of this contract. Notwithstanding that additional 
funds are obligated under this contract through the issuance and 
attachment of the master PSC funding document, all other contract terms 
and conditions remain in full effect.

           Article IV--Costs Reimbursable and Logistic Support

    A. General: The contractor shall be provided with or reimbursed in 
local currency (______) for the following:

                               [Complete]

    B. Method of Payment of Local Currency Costs: Those contract costs 
which are specified as local currency costs in paragraph A above, if not 
furnished in kind by the cooperating government or the Mission, shall be 
paid to the contractor in a manner adapted to the local situation, based 
on vouchers submitted in accordance with General Provision Clause 12. 
The documentation for such costs shall be on such forms and in such 
manner as the Mission Director shall prescribe.

                     Article V--Precontract Expenses

    No expense incurred before execution of this contract will be 
reimbursed unless such expense was incurred after receipt and acceptance 
of a precontract expense letter issued to the contractor by the 
Contracting Officer, and then only in accordance with the provisions and 
limitations contained in such letter. The rights and obligations created 
by such letter shall be considered as merged into this contract.

                     Article VI--Additional Clauses

    (Additional Schedule Clauses may be added such as the implementation 
of General Provisions or Additional Clauses.)

    12. General Provisions

   Contract With a U.S. Citizen or a U.S. Resident Alien for Personal 
                             Services Abroad

    The following clauses are to be used (when applicable), for both 
tours of duty of less than 1 year as well as 1 year or more.

                            INDEX OF CLAUSES

1. Definitions
2. Compliance with Laws and Regulations Applicable Abroad
3. Physical Fitness and Health Room Privileges
4. Workweek and Compensation (Pay Comparability Adjustments)
5. Leave and Holidays
6. Differential and Allowances
7. Social Security, Federal Income Tax, and Foreign Earned Income
8. Advance of Dollar Funds
9. Insurance
10. Travel and Transportation Expenses
11. Payment
12. Conversion of U.S. Dollars to Local Currency
13. Post of Assignment Privileges
14. Security Requirements
15. Contractor-Mission Relationships
16. Termination

[[Page 98]]

17. Release of Information
18. Notices
19. Reports
20. Use of Pouch Facilities
21. Biographical Data
22. U.S. Resident Hire Personal Services Contractor
23. Orientation and Language Training
24. Conditions for Contracting Prior to Receipt of Security Clearance
25. Medical Evacuation (MEDEVAC) Services
26. Governing Law

                       1. Definitions (June 1990)

    (a) USAID shall mean the U.S. Agency for International Development.
    (b) Administrator shall mean the Administrator or the Deputy 
Administrator of USAID.
    (c) Contracting Officer shall mean a person with the authority to 
enter into, administer, and/or terminate contracts and make related 
determinations and findings. The term includes certain authorized 
representatives of the Contracting Officer acting within the limits of 
their authority as delegated by the Contracting Officer.
    (d) Contractor shall mean the individual engaged to serve under this 
contract.
    (e) Cooperating Country shall mean the foreign country in or for 
which services are to be rendered hereunder.
    (f) Cooperating Government shall mean the government of the 
Cooperating Country.
    (g) Government shall mean the United States Government.
    (h) Local currency shall mean the currency of the Cooperating 
Country.
    (i) Mission shall mean the United States USAID Mission, or principal 
USAID office, in the Cooperating Country, or USAID/Washington (USAID/W).
    (j) Mission Director shall mean the principal officer in the Mission 
in the Cooperating Country, or his/her designated representative.
    (k) Technical Officer shall mean the USAID official to whom the 
contractor reports, and who is responsible for monitoring the 
contractor's performance.
    (l) Tour of duty shall mean the contractor's period of service under 
this contract and shall include orientation in the United States (less 
language training), authorized leave, and international travel.
    (m) Traveler shall mean--
    (1) The contractor in authorized travel status or
    (2) Dependents of the contractor who are in authorized travel 
status.
    (n) Dependents means:
    (1)Spouse.
    (2) Children (including step and adopted children) who are unmarried 
and under 21 years of age or, regardless of age, are incapable of self-
support.
    (3) Parents (including step and legally adoptive parents) of the 
employee or of the spouse, when such parents are at least 51 percent 
dependent on the contractor for support.
    (4) Sisters and brothers (including step or adoptive sisters or 
brothers) of the contractor, or of the spouse, when such sisters and 
brothers are at least 51 percent dependent on the contractor for 
support, unmarried and under 21 years of age, or regardless of age, are 
incapable of self-support.
    (o) U.S. Resident Alien, as used in this contract, shall mean an 
alien immigrant, legally resident in the United States, the Commonwealth 
of Puerto Rico, or the possessions of the United States, and having a 
valid ``Alien Registration and Receipt Card'' (Immigration and 
Naturalization Service forms I-151 or I-551).
    (p) U.S. Resident Hire Personal Services Contractor (PSC) means a 
U.S. citizen who, at the time of hiring as a PSC, resides in the 
Cooperating Country:
    (1) As a spouse or dependent of a U.S. citizen employed by a U.S. 
Government Agency or under any U.S. Government-financed contract or 
agreement, or
    (2) For reasons other than for employment with a U.S. Government 
Agency or under any U.S. Government-financed contract or agreement. A 
U.S. citizen for purposes of this definition also includes a person who 
at the time of contracting, is a lawfully admitted permanent resident of 
the United States.

  2. Compliance With Laws and Regulations Applicable Abroad (July 1993)

    (a) Conformity to Laws and Regulations of the Cooperating Country. 
Contractor agrees that, while in the cooperating country, he/she as well 
as authorized dependents will abide by all applicable laws and 
regulations of the cooperating country and political subdivisions 
thereof.
    (b) Purchase or Sale of Personal Property or Automobiles. To the 
extent permitted by the cooperating country, the purchase, sale, import, 
or export of personal property or automobiles in the cooperating country 
by the contractor shall be subject to the same limitations and 
prohibitions which apply to Mission U.S.-citizen direct-hire employees.
    (c) Code of Conduct. The contractor shall, during his/her tour of 
duty under this contract, be considered an ``employee'' (or if his/her 
tour of duty is for less than 130 days, a ``special Government 
employee'') for the purposes of, and shall be subject to, the provisions 
of 18 U.S.C. 202(a) and the USAID General Notice entitled ``Employee 
Review of the New Standards of Conduct'' pursuant to 5 CFR part 2635. 
The contractor acknowledges receipt of a copy of these documents by his/
her acceptance of this contract.

[[Page 99]]

        3. Physical Fitness and Health Room Privileges (Apr 1997)

    (a) Physical Fitness. (1) For all assignments outside of the United 
States the contractor and any authorized dependents shall be required to 
be examined by a licensed doctor of medicine, and the contractor shall 
obtain from the doctor a statement of medical opinion that, in the 
doctor's opinion, the contractor is physically able to engage in the 
type of activity for which he/she is to be employed under the contract, 
and the contractor and any dependents are physically able to reside in 
the Cooperating Country. A copy of the statement(s) shall be provided to 
the Contracting Officer prior to the contractor's departure for the 
Cooperating Country, or for a U.S. resident hire, before he/she starts 
work under the contract.
    (2) For assignments of 60 days or more in the Cooperating Country, 
the Contracting Officer shall provide the contractor and all authorized 
dependents copies of the ``USAID Contractor Employee Physical 
Examination Form''. This form is for collection of information; it has 
been reviewed and approved by OMB, and assigned Control No. 0412-0536. 
Information required by the Paperwork Reduction Act (burden estimate, 
points of contract, and OMB approval expiration date) is printed on the 
form. The contractor and all authorized dependents shall obtain a 
physical examination from a licensed physician, who will complete the 
form for each individual. The contractor will deliver the physical 
examination form(s) to the Embassy health unit in the Cooperating 
Country. A copy of the doctor's statement of medical opinion at the end 
of the form which identifies the contractor or dependent by name may be 
used to meet the requirement in (a)(1) above.
    (3) For end-of-tour the contractor and his/her authorized dependents 
are authorized physical examinations within 60 days after completion of 
the contractor's tour-of-duty.
    (b) Reimbursement. (1) As a contribution to the cost of medical 
examinations required by paragraph (a)(1) of this clause, USAID shall 
reimburse the contractor not to exceed $100 for each physical 
examination, plus reimbursement of charges for immunizations.
    (2) As a contribution to the cost of medical examinations required 
by paragraph (a)(2) of this clause the contractor shall be reimbursed in 
an amount not to exceed half of the cost of the examination up to a 
maximum USAID share of $300 per examination plus reimbursement of 
charges for immunizations for himself/herself and each authorized 
dependent 12 years of age or over. The USAID contribution for authorized 
dependents under 12 years of age shall not exceed half of the cost of 
the examination up to a maximum share of $120 per individual plus 
reimbursement of charges for immunizations. The contractor must obtain 
the prior written approval of the Contracting Officer to receive any 
USAID obligations higher than these limits.
    (c) Health Room Privileges. Routine health room services may be 
available, subject to post policy and in accordance with the 
requirements of paragraph (a) of this clause, to U.S. citizen 
contractors and their authorized dependents (regardless of citizenship) 
at the post of duty. These services do not include hospitalization or 
predeparture examinations. The services normally include such 
medications as may be available, immunizations and preventive health 
measures, diagnostic examinations and advice, and home visits as 
medically indicated. Emergency medical treatment is provided to U.S. 
citizen contractor employees and dependents, whether or not they may 
have been granted access to routine health room services, on the same 
basis as it would be to any U.S. citizen in an emergency medical 
situation in the country.

 4. Workweek and Compensation (Pay Comparability Adjustments) (Dec 1985)

    (a) Workweek. The contractor's workweek shall not be less than 40 
hours, unless otherwise provided in the Contract Schedule, and shall 
coincide with the workweek for those employee of the Mission or the 
Cooperating Country agency most closely associated with the work of this 
contract. If the contract is for less than full time (40 hours weekly), 
the annual and sick leave earned shall be prorated (see the General 
Provision of this contract entitled Leave and Holidays).
    (b) Compensation (Pay Comparability) Adjustments. The contractor's 
compensation shall be adjusted to reflect the pay comparability 
adjustments which are granted from time to time to U.S. direct-hire 
employees by Executive Order for the statutory pay systems. Any 
adjustments authorized are subject to the availability of funds and 
shall not exceed that percentage stated in the Executive Order granting 
the adjustment. Further, the adjusted compensation may not exceed the 
maximum ES-6 annual compensation (or the equivalent daily rate).

                    5. Leave and Holidays (Apr 1997)

    (a) Vacation Leave. (1) The contractor shall earn vacation leave at 
the rate of 13 workdays per annum or 4 hours every 2 weeks. However, no 
vacation shall be earned if the tour of duty is less than 90 days.
    (2) Notwithstanding paragraph (a)(1) above, if the contractor has 
had previous PSC service (i.e., has served under other personal services 
contracts (PSCs) covered by Sec. 636(a)(3) of the FAA), he/she shall 
earn vacation leave at the rate of either 6 hours every two weeks (10 
hours for the final pay period of a calendar year) cumulative PSC 
service exceeding 3 years, or 8 hours every two

[[Page 100]]

weeks for cumulative PSC service exceeding 15 years. Former Civil 
Service, Foreign Service, or a Military Service experience is not 
creditable towards PSC service for annual leave purposes.
    (3) It is understood that vacation leave is provided under this 
contract primarily for the purposes of affording necessary rest and 
recreation during the tour of duty in the Cooperating Country. The 
Contractor in consultation with the USAID Mission shall develop a 
vacation leave schedule early in his/her tour of duty taking into 
consideration project requirements, employee preference and other 
factors. All vacation leave earned by the contractor must be used during 
his/her tour of duty. All vacation leave earned by the contractor but 
not taken by the end of his/her tour of duty will be forfeited unless 
the requirements of the activity precluded the employee from taking such 
leave and the Contracting Officer, with the endorsement of the Mission 
Director, approves one of the following as an alternative:
    (i) Taking leave during the concluding weeks of the employee's tour, 
or
    (ii) Lump-sum payment for leave not taken provided such leave does 
not exceed the number of days which can be earned by the employee during 
a twelve month period.
    (4) With the approval of the Mission Director, and if the 
circumstances warrant, a contractor may be granted advance vacation 
leave in excess in that earned, but in no case shall a contractor be 
granted advance vacation leave in excess of that which he/she will earn 
over the life of the contract. The contractor agrees to reimburse USAID 
for leave used in excess of the amount earned during the contractor's 
assignment under the contract.
    (b) Sick Leave. Sick leave is earned at a rate not to exceed 13 
work-days per annum or 4 hours every 2 weeks. Unused sick leave may be 
carried over under an extension of this contract for the same or similar 
services at the same Mission, but the contractor will not be compensated 
for unused sick leave at the completion of this contract. No leave my be 
carried over from one post to another.
    (c) Home Leave. (1) Home leave is leave earned for service abroad 
for use only in the United States, in the Commonwealth of Puerto Rico, 
or in the possessions of the United States.
    (2) A contractor who is a U.S. citizen or U.S. resident alien and 
has served as least 2 years overseas, as defined in paragraph (c)(4) 
below, under personal services contract in this Mission, and has not 
taken more than 30 workdays leave (vacation, sick, or leave without pay) 
in the United States, may be granted home leave of not more than 15 work 
days for each such year of service overseas; provided, that the 
contractor agrees to return overseas upon completion of home leave under 
an additional 2 year appointment, or for such shorter period of not less 
than 1 year of overseas service under the contract as the Mission 
Director may approve in advance. Home leave must be taken in the United 
States, the Commonwealth of Puerto Rico, or the possessions of the 
United States, and any days spent elsewhere will be charged to vacation 
leave or leave without pay.
    (3) Notwithstanding the requirement in paragraph (c)(2) above that 
the contractor must have served 2 years overseas under personal services 
contract with this Mission to be eligible for home leave, the contractor 
may be granted advance home leave subject to all of the following 
conditions:
    (i) Granting of leave home leave would in each case serve to advance 
the attainment of the objectives of this contract;
    (ii) The contractor has served a minimum of 18 months in the 
Cooperating Country on his/her current tour of duty under this contract; 
and
    (iii) The contractor agrees to return to the Cooperating Country to 
serve out the remainder of his/her current tour of duty and an 
additional 2 year appointment under this or subsequent contract, or such 
other additional appointment of not less than 1 year of overseas service 
as the Mission Director may approve.
    (4) The period of service overseas required under paragraph (c)(2), 
or paragraph (c)(3) above, shall include the actual days in orientation 
in the United States (less language training) and the actual days 
overseas beginning on the date of departure from the U.S. port of 
embarkation on international travel and continuing, inclusive of 
authorized delays enroute, to the date of arrival at the U.S. port of 
debarkation from international travel. Allowable vacation and sick leave 
taken while overseas, but not leave without pay, shall be included in 
the required period of service overseas. An amount equal to the number 
of days of vacation and sick leave taken in the United States, the 
Commonwealth of Puerto Rico, or the possessions of the United States 
will be added to the required period of service overseas.
    (5) Salary during the travel to and from the United States for home 
leave will be limited to the time required for travel by the most 
expeditious air route. The contractor will be responsible for 
reimbursing USAID for payments made during home leave, if, in spite of 
the undertaking of the new appointment, the contractor, except for 
reasons beyond his/her control as determined by the Contracting Officer, 
does not return overseas and complete the additional required service. 
Unused home leave is not reimbursable under this contract.
    (6) To the extent deemed necessary by the Contracting Officer, a 
contractor in the United States on home leave may be authorized to spend 
not more than 5 days in work

[[Page 101]]

status for consultation at USAID/Washington before returning to post 
duty. Consultation at locations other than USAID/Washington as well as 
any time in excess of 5 days spent for consultation, must be approved by 
the Mission Director or the Contracting Officer.
    (d) Holidays. The contractor, while serving abroad, shall be 
entitled to all holidays granted by the Mission to U.S.-citizen direct-
hire employees.
    (e) Military Leave. Military leave of not more than 15 calendar days 
in any calendar year may be granted to a contractor who is a reservist 
of the Armed Forces, provided that military leave has been approved in 
advance by the Contracting Officer or the Mission Director. A copy of 
any such approval shall be part of the contract file.
    (f) Leave Without Pay. Leave without pay may be granted only with 
the written approval of the Contracting Officer or Mission Director.
    (g) Compensatory Time. Compensatory leave may be granted only with 
the written approval of the Contracting Officer or Mission Director in 
rare instances when it has been determined absolutely essential and used 
under those guidelines which apply to direct-hire employees.
    (h) Leave Records. The contractor shall maintain current leave 
records for himself/herself and make them available, as requested by the 
Mission Director or the Contracting Officer.

                6.Differential and Allowances (June 1990)

    (a) The following differential and allowances will be granted to the 
contractor and his/her authorized dependents to the same extent and on 
the same basis as they are granted to U.S. citizen direct-hire employees 
at the Mission by the Standardized Regulations (Government Civilians, 
Foreign Areas), as from time to time amended, except as noted to the 
contrary below:

            Applicable Reference to Standardized Regulations            
------------------------------------------------------------------------
                                                                        
------------------------------------------------------------------------
(1) Post Differential........................  Chapter 500 and Tables in
                                                Chapter 900.            
(2) Living Quarters Allowance................  Section 130.             
(3) Temporary Lodging Allowance..............  Section 120.             
(4) Post Allowance...........................  Section 220.             
(5) Supplemental Post Allowance..............  Section 230.             
(6) Payments During Evacuation...............  Section 600.             
(7) Education Allowance......................  Section 270.             
(8) Separate Maintenance Allowance...........  Section 260.             
(9) Danger Pay Allowance.....................  Section 650.             
(10) Education Travel........................  Section 280.             
------------------------------------------------------------------------

    (1) Post Differential. Post differential is an additional 
compensation for service at places in foreign areas where conditions of 
environment differ substantially from conditions of environment in the 
continental United States and warrant additional compensation as a 
recruitment and retention incentive. In areas where post differential is 
paid to USAID direct-hire employees, post differential not to exceed the 
percentage of salary as is provided such USAID employees in accordance 
with the Standardized Regulations (Government Civilians, Foreign Areas) 
Chapter 500 (except the limitation contained in Section 552, ``Ceiling 
on Payment'') Tables--Chapter 900, as from time to time amended, will be 
reimbursable hereunder for employees in respect to amounts earned during 
the time such employees actually spend overseas on work under this 
contract. When such post differential is provided to the contractor, it 
shall be payable beginning on the date of arrival at the post of 
assignment and continue, including periods away from post on official 
business, until the close of business on the day of departure from post 
of assignment enroute to the United States. Sick or vacation leave taken 
at or away from the post of assignment will not interrupt the continuity 
of the assignment or require a discontinuance of such post differential 
payments, provided such leave is not taken within the United States or 
the territories of the United States. Post differential will not be 
payable while the employee is away from his/her post of assignment for 
purposes of home leave. Short-term employees shall be entitled to pose 
differential beginning with the forty-third (43rd) day at post.
    (2) Living Quarters Allowance. Living quarters allowance is an 
allowance granted to reimburse an employee for substantially all of his/
her cost for either temporary or residence quarters whenever Government-
owned or Government-rented quarters are not provided to him/her at his/
her post without charge. Such costs are those incurred for temporary 
lodging (temporary lodging allowance) or one unit of residence quarters 
(living quarters allowance) and include rent,

[[Page 102]]

plus any costs not included therein for heat, light, fuel, gas, 
electricity and water. The temporary lodging allowance and the living 
quarters allowance are never both payable to an employee for the same 
period of time. The contractor will receive living quarters allowance 
for payment of rent and utilities if such facilities are not supplied. 
Such allowance shall not exceed the amount paid USAID employees of 
equivalent rank in the Cooperating Country, in accordance with either 
the Standardized Regulations (Government Civilians, Foreign Areas), 
Chapter 130, as from time to time amended, or other rates approved by 
the Mission Director. Subject to the written approval of the Mission 
Director, short-term employees may be paid per diem (in lieu of living 
quarters allowance) at rates prescribed by the Federal Travel 
Regulations, as from time to time amended, during the time such short-
term employees spend at posts of duty in the Cooperating Country under 
this contract. In authorizing such per diem rates, the Mission Director 
shall consider the particular circumstances involved with respect to 
each such short-term employee including the extent to which meals and/or 
lodging may be made available without charge or at nominal cost by an 
agency of the United States Government or of the Cooperating Government, 
and similar factors.
    (3) Temporary Lodging Allowance. Temporary lodging allowance is a 
quarters allowance granted to an employee for the reasonable cost of 
temporary quarters incurred by the employee and his/her family for a 
period not in excess of (i) three months after first arrival at a new 
post in a foreign area or a period ending with the occupation of 
residence (permanent) quarters, if earlier, and (ii) one month 
immediately preceding final departure from the post subsequent to the 
necessary vacating of residence quarters. The contractor will receive 
temporary lodging allowance for himself/herself and authorized 
dependents, in lieu of living quarters allowance, not to exceed the 
amount set forth in the Standardized Regulations (Government Civilians, 
Foreign Areas), Chapter 120, as from time to time amended.
    (4) Post Allowance. Post allowance is a cost-of-living allowance 
granted to an employee officially stationed at a post where the cost of 
living, exclusive of quarters cost, is substantially higher than in 
Washington, D.C. The contractor will receive post allowance payments not 
to exceed those paid USAID employees in the Cooperating Country, in 
accordance with the Standardized Regulations (Government Civilians, 
Foreign Areas), Chapter 220, as from time to time amended.
    (5) Supplemental Post Allowance. Supplemental post allowance is a 
form of post allowance granted to an employee at his/her post when it is 
determined that assistance is necessary to defray extraordinary 
subsistence costs. The contractor will receive supplemental post 
allowance payments not to exceed the amount set forth in the 
Standardized Regulations (Government Civilians, Foreign Areas), Chapter 
230, as from time to time amended.
    (6)  Payments During Evacuation. The Standardized Regulations 
(Government Civilians, Foreign Areas) provide the authority for 
efficient, orderly, and equitable procedure for the payment of 
compensation, post differential and allowances in the event of an 
emergency evacuation of employees or their dependents, or both, from 
duty stations for military or other reasons or because of imminent 
danger to their lives. If evacuation has been authorized by the Mission 
Director, the contractor will receive payments during evacuation for 
himself/herself and authorized dependents evacuated from their post of 
assignment in accordance with the Standardized Regulations (Government 
Civilians, Foreign Areas), Chapter 600, and the Federal Travel 
Regulations, as from time to time amended.
    (7) Educational Allowance. Educational allowance is an allowance to 
assist the contractor in meeting the extraordinary and necessary 
expenses, not otherwise compensated for, incurred by reason of his/her 
service in a foreign area in providing adequate elementary and secondary 
education for his/her children. The contractor will receive educational 
allowance payments for his/her dependent children in amounts not to 
exceed those set forth in Standardized Regulations (Government 
Civilians, Foreign Areas), Chapter 270, as from time to time amended.
    (8) Separate Maintenance Allowance. Separate maintenance allowance 
is an allowance to assist an employee who is compelled by reason of 
dangerous, notably unhealthful, or excessively adverse living conditions 
at his/her post of assignment in a foreign area, or for the convenience 
of the Government, to meet the additional expense of maintaining his/her 
dependents elsewhere than at such post. The contractor will receive 
separate maintenance allowance payments not to exceed that made to USAID 
employees in accordance with the Standardized Regulations (Government 
Civilians, Foreign Areas), Chapter 260, as from time to time amended.
    (9) Danger Pay Allowance. Danger pay allowance is an allowance to 
provide additional compensation above basic compensation to employees in 
foreign areas where civil insurrection, civil war, terrorism or wartime 
conditions threaten physical harm or imminent danger to the health or 
well-being of the employee. The danger pay allowance is in lieu of that 
part of the post differential which is attributable to political 
violence. Consequently, the post differential may be reduced while 
danger pay is in effect to avoid dual crediting for political violence.

[[Page 103]]

The contractor shall be allowed danger pay allowance not to exceed that 
paid USAID employees in the Cooperating Country, in accordance with the 
Standardized Regulations (Government Civilians, Foreign Areas), Chapter 
650, as from time to time amended.
    (10) Educational Travel. Educational travel is travel to and from a 
school in the United States for secondary education (in lieu of an 
educational allowance) and for college education. The contractor will 
receive educational travel payments for his/her dependent children 
provided such payment does not exceed that which would be payable in 
accordance with the Standardized Regulations (Government Civilians, 
Foreign Areas), Chapter 280, as from time to time amended. Educational 
travel shall not be authorized for contractors whose assignment is less 
than two years.
    (b) The allowances provided in paragraphs (a) (1) through (10) of 
this provision shall be paid to the contractor in dollars or in the 
currency of the Cooperating Country in accordance with practice 
prevailing at the Mission, or the Mission Director may direct that the 
contractor be paid a per diem in lieu thereof as prescribed by the 
Standardized Regulations (Government Civilians, Foreign Areas), as from 
time to time amended.

7. Social Security, Federal Income Tax, and Foreign Earned Income (June 
                                  1990)

    (a) Since the contractor is an employee, F.I.C.A. contributions and 
U.S. Federal Income Tax withholding shall be deducted in accordance with 
regulations and rulings of the Social Security Administration and the 
U.S. Internal Revenue Service, respectively.
    (b) As an employee, the contractor is not eligible for the ``foreign 
earned income'' exclusion under the IRS Regulations (see 26 CFR 1.911-
3(c)(3)).

                  8. Advance of Dollar Funds (Apr 1997)

    If requested by the contractor and authorized in writing by the 
Contracting Officer, USAID will arrange for an advance of funds to 
defray the initial cost of travel, travel allowances, authorized 
precontract expenses, and shipment of personal property. The advance 
shall be granted on the same basis as to a USAID U.S.-citizen direct-
hire employee in accordance with USAID Handbook 22, Chapter 4 or 
superseding ADS Chapter.

                         9. Insurance (Apr 1997)

    (a) Worker's Compensation Benefits. The contractor shall be provided 
worker's compensation benefits in accordance with the Federal Employees' 
Compensation Act.
    (b) Health and Life Insurance. (1) The contractor shall be provided 
a maximum contribution of up to 50% against the actual costs of the 
contractor's annual health insurance costs, provided that such costs may 
not exceed the maximum U.S. Government contribution for direct-hire 
personnel as announced annually by the Office of Personnel Management.
    (2) The contractor shall be provided a contribution of up to 50% 
against the actual costs of annual life insurance not to exceed $500.00 
per year.
    (3) Retired U.S. Government employees shall not be paid additional 
contributions for health or life insurance under their contracts. The 
Government will normally have already paid its contribution for the 
retiree unless the employee can prove to the satisfaction of the 
Contracting Officer that his/her health and life insurance does not 
provide or specifically excludes coverage overseas. In such case, the 
contractor would be eligible for contributions under paragraphs (b) (1) 
or (2) as appropriate.
    (4) Proof of health and life insurance coverage shall be submitted 
to the Contracting Officer before any contribution is paid. On 
assignments of less than one year, costs for health and life insurance 
shall be prorated and paid accordingly.
    (5) A contractor who is a spouse of a current or retired Civil 
Service, Foreign Service, or Military Service member and who is covered 
by their spouse's Government health or life insurance policy is 
ineligible for the contribution under paragraphs (b)(1) or (b)(2) of 
this provision.
    (c) Insurance on Private Automobiles. If the contractor or his/her 
dependents transport, or cause to be transported, privately owned 
automobile(s) to the Cooperating Country, or any of them purchase an 
automobile within the Cooperating Country, the contractor agrees to 
ensure that all such automobile(s) during such ownership within the 
Cooperating Country will be covered by a current, i.e., not in arrears, 
insurance policy issued by a reliable company providing the following 
minimum coverage, or such other minimum coverage as may be set by the 
Mission Director, payable in U.S. dollars or its equivalent in the 
currency of the Cooperating Country: injury to persons, $10,000/$20,000; 
property damage, $5,000. The contractor further agrees to deliver, or 
cause to be delivered to the Mission Director, the insurance policies 
required by this clause or satisfactory proof of the existence thereof, 
before such automobile(s) operated within the Cooperating Country. The 
premium costs for such insurance shall not be a reimbursable cost under 
this contract.

           10. Travel and Transportation Expenses (July 1993)

    (a) General. (1) USAID/Washington Office of Administrative Services, 
or such other office as may be designated by that office, may furnish 
Transportation Requests (TR's) to the contractor for transportation 
authorized by this contract originating in the United

[[Page 104]]

States, and the executive or administrative officer at the Mission may 
furnish TR's for such authorized transportation which is payable in 
local currency or is to originate overseas. When transportation is not 
provided by the Government-issued TR, the contractor shall procure his/
her own transportation, the costs of which will be reimbursed in 
accordance with the terms of this contract.
    (2) The contractor will be reimbursed for reasonable, allocable and 
allowable travel and transportation expenses incurred under and for the 
performance of this contract. Determination of reasonableness, 
allocability and allowability will be made by the Contracting Officer in 
accordance with USAID's established policies and procedures for USAID 
direct-hire employees, and the particular needs of the activity being 
implemented by this contract. The following paragraphs provide specific 
guidance and limitations on particular items of cost.
    (b) U.S. Travel and Transportation. The contractor shall be 
reimbursed for actual transportation costs and travel allowances in the 
United States as authorized in the Contract Schedule or approved in 
advance by the Contracting Officer or the Mission Director. 
Transportation costs and travel allowances shall not be reimbursed in 
any amount greater than the cost of, and time required for, economy-
class commercially scheduled air travel by the most expeditious route 
except as otherwise provided in paragraph (g) of this provision unless 
economy air travel is not available and the contractor certifies to this 
in his/her voucher or other documents submitted for reimbursement.
    (c) International Travel. For travel to and from post of assignment, 
the contractor shall be reimbursed for travel costs and travel 
allowances from place of residence in the United States (or other 
location provided that the cost of such travel does not exceed the cost 
of the travel from the contractor's residence in the United States) to 
the post of duty in the Cooperating Country and return to place of 
residence in the United States (or other location provided that the cost 
of such travel does not exceed the cost of travel from the post of duty 
in the Cooperating Country to the contractor's residence) upon 
completion of services by the individual. Reimbursement for travel will 
be in accordance with USAID's established policies and procedures for 
its direct-hire employees and the provisions of this contract, and will 
be limited to the cost of travel by the most direct and expeditious 
route. If the contract is for longer than one year and the contractor 
does not complete one full year at post of duty (except for reasons 
beyond his/her control), the costs of going to and from the post of duty 
for the contractor and his/her dependents are not reimbursable 
hereunder. If the contractor serves more than one year but less than the 
required service in the Cooperating Country (except for reasons beyond 
his/her control) the costs of going to the post of duty are reimbursable 
hereunder but the costs of going from post of duty to the contractor's 
permanent, legal place of residence at the time he or she was employed 
for work under this contract, or other location as approved by the 
Contracting Officer, are not reimbursable under this contract for the 
contractor and his/her dependents. When travel is by economy class 
accommodations, the contractor will be reimbursed for the cost of 
transporting up to 10 kilograms/22 pounds of accompanied personal 
baggage per traveler in addition to that regularly allowed with the 
economy ticket provided that the total number of pounds of baggage does 
not exceed that regularly allowed for first class travelers. Travel 
allowances for travelers shall not be in excess of the rates authorized 
in the Standardized Regulations (Government Civilians, Foreign Areas)-
hereinafter referred to as the Standardized Regulations--as from time to 
time amended, for not more than the travel time required by scheduled 
commercial air carrier using the most expeditious route. One stopover 
enroute for a period of not to exceed 24 hours is allowable when the 
traveler uses economy class accommodations for a trip of 14 hours or 
more of scheduled duration. Such stopover shall not be authorized when 
travel is by indirect route or is delayed for the convenience of the 
traveler. Per diem during such stopover shall be paid in accordance with 
the Federal Travel Regulations as from time to time amended.
    (d) Local Travel. Reimbursement for local travel in connection with 
duties directly referable to the contract shall not be in excess of the 
rates established by the Mission Director for the travel costs of 
travelers in the Cooperating Country. In the absence of such established 
rates the contractor shall be reimbursed for actual travel costs in the 
Cooperating Country or the Mission, including travel allowances at rates 
not in excess of those prescribed by the Standardized Regulations.
    (e) Indirect Travel for Personal Convenience. When travel is 
performed by an indirect route for the personal convenience of the 
traveler, the allowable costs of such travel will be computed on the 
basis of the cost of allowable air fare via the direct usually traveled 
route. If such costs include fares for air or ocean travel by foreign 
flag carriers, approval for indirect travel by such foreign flag 
carriers must be obtained from the Contracting Officer or the Mission 
Director before such travel is undertaken, otherwise only that portion 
of travel accomplished by the United States-flag carriers will be 
reimbursable within the above limitation of allowable costs.
    (f) Limitation on Travel by Dependents. Travel costs and allowances 
will be allowed for authorized dependents of the contractor and such 
costs shall be reimbursed for travel

[[Page 105]]

from place of abode to assigned station in the Cooperating Country and 
returned, only if the dependent remains in the Cooperating Country for 
at least 9 months or one-half of the required tour of duty of the 
contractor, whichever is greater, except as otherwise authorized 
hereunder for education, medical or emergency visitation travel. If the 
dependent is eligible for educational travel pursuant to the 
``Differential and Allowances'' clause of this contract, time spent away 
from post resulting from educational travel will be counted as time at 
post.
    (g) Delays Enroute. The contractor may be granted reasonable delays 
enroute while in travel status when such delays are caused by events 
beyond the control of the contractor and are not due to circuitous 
routine. It is understood that if delay is caused by physical 
incapacitation, he/she shall be eligible for such sick leave as provided 
under the ``Leave and Holidays'' clause of this contract.
    (h) Travel by Privately Owned Automobile (POV). If travel by POV is 
authorized in the contract schedule or approved by the Contracting 
Officer, the contractor shall be reimbursed for the cost of travel 
performed in his/her POV at a rate not to exceed that authorized in the 
Federal Travel Regulations plus authorized per diem for the employee and 
for each of the authorized dependents traveling in the POV, if the POV 
is being driven to or from the Cooperating Country as authorized under 
the contract, provided that the total cost of the mileage and the per 
diem paid to all authorized travelers shall not exceed the total 
constructive cost of fare and normal per diem by all authorized 
travelers by surface common carrier or authorized air fare, whichever is 
less.
    (i) Emergency and Irregular Travel and Transportation. Emergency 
transportation costs and travel allowances while enroute, as provided in 
this section, will be reimbursed not to exceed amounts authorized by the 
Foreign Service Travel Regulations for USAID-direct hire employees in 
like circumstances under the following conditions:
    (1) The costs of going from post of duty in the Cooperating Country 
to the employee's permanent, legal place of residence at the time he or 
she was employed for work under this contract or other location for 
contractor employees and dependents and returning to the post of duty, 
subject to the prior written approval of the Mission Director that such 
travel is necessary for one of the following reasons.
    (i) Need for medical care beyond that available within the area to 
which the employee is assigned, or serious effect on physical or mental 
health if residence is continued at assigned post of duty. The Mission 
Director may authorize a medical attendant to accompany the employee at 
contract expense if, based on medical opinion, such an attendant is 
necessary.
    (ii) Death, or serious illness or injury of a member of the 
immediate family of the employee or the immediate family of the 
employee's spouse.
    (2) When, for any reason, the Mission Director determines it is 
necessary to evacuate the contractor or contractor's dependents, the 
contractor will be reimbursed for travel and transportation expenses and 
travel allowance while enroute, for the cost of the individuals going 
from post of duty in the Cooperating Country to the employee's 
permanent, legal place of residence at the time he or she was employed 
for work under this contract or other approved location. The return of 
such employees and dependents may also be authorized by the Mission 
Director when, in his/her discretion, he/she determines it is prudent to 
do so.
    (3) The Mission Director may also authorize emergency or irregular 
travel and transportation in other situations, when in his/her opinion, 
the circumstances warrant such action. The authorization shall include 
the kind of leave to be used and appropriate restrictions as to time 
away from post, transportation of personal and household effects, etc.
    (j) Home Leave Travel. To the extend that home leave has been 
authorized as provided in the ``Leave and Holidays'' clause of this 
contract, the cost of travel for home leave is reimbursable for travel 
costs and travel allowances of travelers from the post of duty in the 
Cooperating Country to place of residence in the United States (or other 
location provided that the cost of such travel does not exceed the cost 
of travel to the contractor's residence in the United States) and return 
to the post of duty in the Cooperating Country. Reimbursement for travel 
will be in accordance with the Uniform State/USAID/USIA Foreign Service 
Travel Regulations, as from time to time amended, and will be limited to 
the cost of travel by the most direct and expeditious route. Travel 
allowances for travelers shall be in accordance with the rates 
authorized in the Standardized Regulations as from time to time amended, 
for not more than the travel time required by scheduled commercial air 
carrier using the most expeditious route using economy class. One 
stopover enroute for a period of not to exceed 24 hours is allowable 
when the traveler uses economy class accommodations for a trip of 14 
hours or more of scheduled duration. Such stopover shall not be 
authorized when travel is by indirect route or is delayed for the 
convenience of the traveler or the traveler uses other than economy 
class. Per diem during such stopover shall be paid in accordance with 
the Standardized Regulations.
    (k) Rest and Recuperations Travel. If approved in writing by the 
Mission Director,

[[Page 106]]

the contractor and his/her dependents shall be allowed rest and 
recuperation travel on the same basis as authorized USAID direct-hire 
Mission employees and their dependents.
    (l) Transportation of Motor Vehicles, Personal Effects and Household 
Goods.
    (1) Transportation costs will be paid on the same basis as for USAID 
direct-hire employees serving the same length tour of duty, as 
authorized in the schedule. Transportation, including packing and 
crating costs, will be paid for shipping from the point of origin in the 
United States (or other location as approved by the Contracting Officer) 
to post of duty in the Cooperating Country and return to point of origin 
in the United States (or other location as approved by the Contracting 
Officer) of one privately-owned vehicle for the contractor, personal 
effects of the contractor and authorized dependents, and household goods 
of the contractor not to exceed the limitations in effect for such 
shipments for USAID direct-hire employees in accordance with the Foreign 
Service Travel Regulations in effect at the time shipment is made. These 
limitations may be obtained from the Contracting Officer.
    (2) The cost of transporting motor vehicles and household goods 
shall not exceed the cost of packing, crating, and transportation by 
surface common carrier. In the event that the carrier does not require 
boxing or crating of motor vehicles for shipment to the Cooperating 
Country, the cost of boxing or crating is not reimbursable. The 
transportation of a privately owned motor vehicle for a contractor may 
be authorized as a replacement of the last such motor vehicle shipped 
under this contract for such contractor when the Mission Director 
determines, in advance, and so notifies the contractor in writing, that 
the replacement is necessary for reasons not due to the negligence or 
malfeasance of the contractor. The determination shall be made under the 
same rules and regulations that apply to authorized Mission U.S. citizen 
direct-hire employees.
    (m) Unaccompanied Baggage. Unaccompanied baggage is considered to be 
those personal belongings needed by the traveler immediately upon 
arrival of the contractor and dependents, and consideration should be 
given to advance shipments of unaccompanied baggage. The contractor will 
be reimbursed for costs of shipment of unaccompanied baggage (in 
addition to the weight allowance for household effects) not to exceed 
the limitations in effect for USAID direct-hire employees in accordance 
with the Foreign Service Travel Regulations as in effect when shipment 
is made. These limitations are available from the Contracting Officer. 
This unaccompanied baggage may be shipped as air freight by the most 
direct route between authorized points of origin and destination 
regardless of the modes of travel used. This provision is applicable to 
home leave travel when authorized by the terms of this contract.
    (n) International Ocean Transportation. (1)(i) Transportaiton of 
things. Where U.S. flag vessels are not available, or their use would 
result in a significant delay, the contractor may obtain a release from 
the requirement to use U.S. flag vessels from the Transportation 
Division, Office of Procurement, U.S. Agency for International 
Development, Washington, D.C. 20523-1419, or the Mission Director, as 
appropriate, giving the basis for the request.
    (ii) Transportation of persons. Where U.S. flag vessels are not 
available, or their use would result in a significant delay, the 
contractor may obtain a release from the requirement to use U.S. flag 
vessels from the Contracting Officer or the Mission Director, as 
appropriate.
    (2) Transportation of foreign-made vehicles. Reimbursement of the 
costs of transporting a foreign-made motor vehicle will be made in 
accordance with the provisions of the Foreign Service Travel 
Regulations.
    (3) Reduced rates on U.S.-flag carriers are in effect for shipments 
of household goods and personal effects of USAID contractors between 
certain locations. These reduced rates are available provided the 
shipper furnishes to the carrier at the time of the issuance of the Bill 
of Lading documentary evidence that the shipment is for the account of 
USAID. The Contracting Officer will, on request, furnish to the 
contractor current information concerning the availability of a reduced 
rate with respect to any proposed shipment. The contractor will not be 
reimbursed for shipments of household goods or personal effects in 
amounts in excess of the reduced rates which are available in accordance 
with the foregoing.
    (o) Storage of household effects. The cost of storage charges 
(including packing, crating, and drayage costs) in the U.S. of household 
goods of the contractor will be permitted in lieu of transportation of 
all or any part of such goods to the Cooperating Country under paragraph 
(l) above provided that the total amount of effects shipped to the 
Cooperating Country or stored in the U.S. shall not exceed the amount 
authorized for USAID direct-hire employees under the Uniform Foreign 
Service Travel Regulations. These amounts are available from the 
Contracting Officer.

                         11. Payment (Aug 1996)

    (a) Once each month, or at more frequent intervals, if approved by 
the paying office indicated on the Cover Page, the contractor may submit 
to such office form SF 1034 ``Public Voucher for Purchases and Services 
Other Than Personal'' (original) and SF 1034-A (three copies), or 
whatever other form is locally required or accepted. Each voucher

[[Page 107]]

shall be identified by the USAID contract number and properly executed 
in the amount of dollars claimed during the period covered. The voucher 
forms shall be supported by:
    (1) The contractor's detailed invoice, in original and two copies, 
indicating for each amount claimed the paragraph of the contract under 
which payment is to be made, supported when applicable as follows:
    (i) For compensation--a statement showing period covered, days 
worked, and days when contractor was in authorized travel, leave, or 
stopover status for which compensation is claimed. All claims for 
compensation will be accompanied by, or will incorporate, a 
certification signed by the Project Officer covering days or hours 
worked, or authorized travel or leave time for which compensation is 
claimed.
    (ii) For travel and transportation--a statement of itinerary with 
attached carrier's receipt and/or passenger's coupons, as appropriate.
    (iii) For reimbursable expenses--an itemized statement supported by 
original receipts.
    (2) The first voucher submitted shall account for, and liquidate the 
unexpended balance of any funds advanced to the contractor.
    (b) A final voucher shall be submitted by the contractor promptly 
following completion of the duties under this contract but in no event 
later than 120 days (or such longer period as the Contracting Officer 
may in his/her discretion approve in writing) from the date of such 
completion. The contractor's claim, which includes his/her final 
settlement of compensation, shall not be paid until after the 
performance of the duties required under the terms of this contract has 
been approved by USAID. On receipt and approval of the voucher 
designated by the contractor as the ``final voucher'' submitted on Form 
SF 1034 (original) and SF 1034-A (three copies), together with a refund 
check for the balance remaining on hand of any funds which may have been 
advanced to the contractor, the Government shall pay any amounts due and 
owing the contractor.
    (c) If approved by the paying office time and attendance may be 
submitted for PSCs in the same manner as is approved for direct-hire 
personnel.

       12. Conversion of U.S. Dollars to Local Currency (Dec 1985)

    Upon arrival in the Cooperating Country, and from time to time as 
appropriate, the contractor shall consult with the Mission Director or 
his/her authorized representative who shall provide, in writing, the 
policy the contractor shall follow in the conversion of U.S. dollars to 
local currency. This may include, but not be limited to the conversion 
of said currency through the cognizant U.S. Disbursing Officer, or 
Mission Controller, as appropriate.

              13. Post of Assignment Privileges (July 1993)

    Privileges such as the use of APO, PX's, commissaries and officers 
clubs are established at posts abroad under agreements between the U.S. 
and host governments. These facilities are intended for and usually 
limited to members of the official U.S. establishment including the 
Embassy, USAID Mission, U.S. Information Service and the Military. 
Normally, the agreements do not permit these facilities to be made 
available to non-official Americans. However, in those cases where 
facilities are open to non-official Americans, they may be used.

                  14. Security Requirements (June 1990)

    (a) This entire provision shall apply to the extent that this 
contract involves access to classified information (``Confidential'', 
``Secret'', or ``Top Secret'') or access to administratively controlled 
information (``Limited Official Use''). Contractors that are not U.S. 
citizens shall not have access to classified or administratively 
controlled information.
    (b) The contractor (1) shall be responsible for safeguarding all 
classified or administratively controlled information in accordance with 
appropriate instructions furnished by the USAID Office of Security (IG/
SEC), as referenced in paragraph (d) of this provision and shall not 
supply, disclose, or otherwise permit access to classified information 
or administratively controlled information to any unauthorized person; 
(2) shall not make or permit to be made any reproductions of classified 
information or administratively controlled information except with the 
prior written authorization of the Contracting Officer or Mission 
Director; (3) shall submit to the Contracting Officer, at such times as 
the Contracting Officer may direct, an accounting of all reproductions 
of classified or administratively controlled information; and (4) shall 
not incorporate in any other project any matter which will disclose 
classified and/or administratively controlled information except with 
the prior written authorization of the Contracting Officer.
    (c) The contractor shall follow the procedures for classifying, 
marking, handling, transmitting, disseminating, storing, and destroying 
official material in accordance with the regulations in the Foreign 
Affairs Manual, Chapter 5 (5 FAM 900), a copy of which will be furnished 
by the Contracting Officer or Mission Director.
    (d) The contractor agrees to submit immediately to the Mission 
Director or Contracting Officer a complete detailed report, 
appropriately classified, of any information which the contractor may 
have concerning existing or threatened espionage, sabotage, or 
subversive activity.

[[Page 108]]

    (e) The Government agrees that, when necessary, it shall indicate by 
security classification or administratively controlled designation, the 
degree of importance to the national defense of information to be 
furnished by the contractor to the Government or by the Government to 
the contractor, and the Government shall give written notice of such 
security classification or administratively controlled designation to 
the contractor and of any subsequent changes thereof. The contractor is 
authorized to rely on any letter or other written instrument signed by 
the Contracting Officer changing a security classification or 
administratively controlled designation of information.
    (f) The contractor agrees to certify after completion of his/her 
assignment under this contract that he/she has surrendered or disposed 
of all classified and/or administratively controlled information in his/
her custody in accordance with applicable security instructions.

             15. Contractor-Mission Relationships (Dec 1985)

    (a) The contractor acknowledges that this contract is an important 
part of the U.S. Foreign Assistance Program and agrees that his/her 
duties will be carried out in such a manner as to be fully commensurate 
with the responsibilities which this entails.
    (b) While in the Cooperating Country, the contractor is expected to 
show respect for the conventions, customs, and institutions of the 
Cooperating Country and not interfere in its political affairs.
    (c) If the contractor's conduct is not in accordance with paragraph 
(b) of this provision, the contract may be terminated under General 
Provision 16 of this contract. The Contractor recognizes the right of 
the U.S. Ambassador to direct his/her immediate removal from any country 
when, in the discretion of the Ambassador, the interests of the United 
States so require.
    (d) The Mission Director is the chief representative of USAID in the 
Cooperating Country. In this capacity, he/she is responsible for the 
total USAID Program in the Cooperating Country including certain 
administrative responsibilities set forth in this contract and for 
advising USAID regarding the performance of the work under the contract 
and its effect on the U.S. Foreign Assistance Program. The contractor 
will be responsible for performing his/her duties in accordance with the 
statement of duties called for by the contract. However, he/she shall be 
under the general policy guidance of the Mission Director, and shall 
keep the Mission Director or his/her designated representative currently 
informed of the progress of the work under this contract.

                       16. Termination (Nov 1989)

    (This is an approved deviation to be used in place of the clause 
specified in FAR 52.249-12.)
    (a) The Government may terminate performance of work under this 
contract in whole or, from time to time, in part:
    (1) For cause, which may be effected immediately after establishing 
the facts warranting the termination, by giving written notice and a 
statement of reasons to the contractor in the event (i) the Contractor 
commits a breach or violation of any obligations herein contained, (ii) 
a fraud was committed in obtaining this contract, or (iii) the 
contractor is guilty (as determined by USAID) of misconduct in the 
Cooperating Country. Upon such a termination, the contractor's right to 
compensation shall cease when the period specified in such notice 
expires or the last day on which the contractor performs services 
hereunder, whichever is earlier. No costs of any kind incurred by the 
contractor after the date such notice is delivered shall be reimbursed 
hereunder except the cost of return transportation (not including travel 
allowances), if approved by the Contracting Officer. If any costs 
relating to the period subsequent to such date have been paid by USAID, 
the contractor shall promptly refund to USAID any such prepayment as 
directed by the Contracting Officer.
    (2) For the convenience of USAID, by giving not less than 15 
calendar days advance written notice to the contractor. Upon such a 
termination, contractor's right to compensation shall cease when the 
period specified in such notice expires except that the contractor shall 
be entitled to any unused vacation leave, return transportation costs 
and travel allowances and transportation of unaccompanied baggage costs 
at the rate specified in the contract and subject to the limitations 
which apply to authorized travel status.
    (3) For the convenience of USAID, when the contractor is unable to 
complete performance of his/her services under the contract by reason of 
sickness or physical or emotional incapacity based upon a certification 
of such circumstances by a duly qualified doctor of medicine approved by 
the Mission. The contract shall be deemed terminated upon delivery to 
the Contractor of a termination notice. Upon such a termination, the 
contractor shall not be entitled to compensation except to the extent of 
any unused vacation or sick leave but shall be entitled to return 
transportation, travel allowances, and unaccompanied baggage costs at 
rates specified in the contract and subject to the limitations which 
apply to authorized travel status.

[[Page 109]]

    (b) The contractor, with the written consent of the Contracting 
Officer, may terminate this contract upon at least 15 days' written 
notice to the Contracting Officer.

                  17. Release of Information (Dec 1985)

    All rights in data and reports shall become the property of the U.S. 
Government. All information gathered under this contract by the 
Contractor and all reports and recommendations hereunder shall be 
treated as confidential by the Contractor and shall not, without the 
prior written approval of the Contracting Officer, be made available to 
any person, party, or government, other than USAID, except as otherwise 
expressly provided in this contract.

                         18. Notices (Dec 1985)

    Any notice, given by any of the parties hereunder, shall be 
sufficient only if in writing and delivered in person or sent by 
telegraph, telegram, registered, or regular mail as follows:
    To USAID: Administrator, U.S. Agency for International Development, 
Washington, D.C. 20523-0001, Attention: Contracting Officer.
    (name of the cognizant Contracting Officer with a copy to the 
appropriate Mission Director).
    To Contractor:
    At his/her post of duty while in the Cooperating Country and at the 
Contractor's address shown on the Cover Page of this contract or to such 
other address as either of such parties shall designate by notice given 
as herein required. Notices hereunder shall be effective in accordance 
with this clause or on the effective date of the notice, whichever is 
later.

                         19. Reports (June 1987)

    (a) The Contractor shall prepare and submit 2 copies of each 
technical report required by the schedule of this contract to the Bureau 
for Program and Policy Coordination, Center for Development Information 
and Evaluation, Development Information Division (PPC/CDIE/DI). All 
documents should be mailed to:
    PPC/CDIE/DI, Acquisitions, Room 209, SA-18, U.S. Agency for 
International Development, Washington, D.C. 20523-1802.
    The title page of all reports forwarded to PPC/CDIE/DI pursuant to 
this paragraph shall include a descriptive title, the author's name(s), 
contract number, project number and title, contractor's name, name of 
the USAID project office, and the publication or insurance date of the 
report.
    (b) When preparing reports, the contractor shall refrain from using 
elaborate art work, multicolor printing and expensive paper/binding, 
unless it is specifically authorized in the Contract Schedule. Wherever 
possible, pages should be printed on both sides using single spaced 
type.

                 20. Use of Pouch Facilities (July 1993)

    (a) Use of diplomatic pouch is controlled by the Department of 
State. The Department of State has authorized the use of pouch 
facilities for USAID contractors and their employees as a general 
policy, as detailed in paragraphs (a)(1) through (a)(6) of this 
provision. However, the final decision regarding use of pouch facilities 
rests with the Embassy or USAID Mission. In consideration of the use of 
pouch facilities as hereinafter stated, the Contractor agrees to 
indemnify and hold harmless the Department of State and USAID for loss 
or damage occurring in pouch transmission.
    (1) Contractors are authorized use of the pouch for transmission and 
receipt of up to a maximum of 0.90 kilogram/2 pounds per shipment of 
correspondence and documents needed in the administration of foreign 
assistance programs.
    (2) U.S. citizen contractors are authorized use of the pouch for 
personal mail up to a maximum of 0.45 kilogram/one pound per shipment 
(but see (a)(3) below). Non-U.S. citizen Contractors are not permitted 
use of the pouch for personal mail except to the extent that such use 
may be authorized by the Chief of Mission.
    (3) Merchandise, parcels, magazines, or newspapers are not 
considered to be personal mail for purpose of this clause, and are not 
authorized to be sent or received by pouch.
    (4) Official and personal mail under paragraphs (a) (1) and (2) of 
this provision, sent by pouch, should be addressed as follows:
    Individual's Name (C), U.S. Agency for International Development, 
Washington, D.C. 20523-0001.
    (5) Mail sent via the diplomatic pouch may not be in violation of 
U.S. Postal laws and may not contain material ineligible for pouch 
transmission.
    (6) Use of military postal facilities (APO/FPO) is authorized to 
U.S. contractors on the same basis as approved for direct-hire employees 
at the USAID Mission. Posts having access to APO/FPO facilities and 
using such for diplomatic pouch dispatch, may, however, accept official 
and personal mail for the pouch provided, of course, adequate postage is 
affixed when onward transmission (mail to other than USAID/W) through 
U.S. postal channels is required.
    (b) The contractor shall be responsible for compliance with these 
guidelines and limitations on use of pouch facilities.
    (c) Specific additional guidance on use of pouch facilities in 
accordance with this clause is available from the Post Communication 
Center at the Embassy or USAID Mission.

[[Page 110]]

                    21. Biographical Data (June 1990)

    (a) The contractor agrees to furnish biographical information to the 
Contracting Officer on forms (SF 171 and 171As) provided for that 
purpose.
    (b) Emergency locator information. The contractor agrees to provide 
the following information to the Mission Administrative Officer on 
arrival in the host country regarding himself/herself and dependents:
    (1) Contractor's full name, home address, and telephone number 
including any after-hours emergency number(s).
    (2) The name and number of the contract, and whether the individual 
is the contractor or the contractor's dependent.
    (3) The name, address, and home and office telephone number(s) of 
each individual's next of kin.
    (4) Any special instructions pertaining to emergency situations such 
as power of attorney designees or alternate contact persons.

     22. U.S. Resident Hire Personal Services Contractor (June 1990)

    A contractor meeting the definition of a U.S. Resident Hire PSC 
contained in Section 12, General Provisions, Clause 1, Definitions, 
shall be subject to U.S. Federal Income Tax, but shall not be eligible 
for any fringe benefits (except contributions for FICA, health insurance 
and life insurance), allowances, or differentials, including but not 
limited to travel and transportation, medical, orientation, home leave, 
etc., unless such individual can demonstrate to the satisfaction of the 
Contracting Officer that he/she has received similar benefits/allowances 
from their immediately previous employer in the Cooperating Country, or 
the Mission Director determines that payment of such benefits would be 
consistent with the Mission's policy and practice and would be in the 
best interest of the U.S. Government.

            23. Orientation and Language Training (July 1993)

    (a) Except as set forth in paragraph (b)(4) below, the Contractor 
shall receive a maximum of 2 weeks USAID orientation before travel 
overseas. The dates of orientation shall be selected by the Contractor 
and approved by the Contracting Officer from the orientation schedule 
provided by USAID.
    (b) As either set forth in the Contract Schedule, or provided in 
writing by the Contracting Officer, the following may be authorized 
taking into consideration specific job requirements, contractor's prior 
overseas experience, or unusual circumstances, in connection with 
orientation of individual Contractors:
    (1) Modified orientation,
    (2) Language training,
    (3) Orientation for Contractor's dependents at contract expense.
    (4) Waiver of orientation for individual contractor.
    (c) Transportation costs and travel allowances not to exceed one 
round trip from the Contractor's residence to place of orientation and 
return will be reimbursed, pursuant to Clause 10 of the General 
Provisions, entitled ``Travel and Transportation Expenses,'' if the 
orientation is more than 80 kilometers/50 miles from the contractor's 
residence.
    Allowable salary costs during the period of orientation are also 
reimbursable.

 24. Conditions for Contracting Prior to Receipt of Security Clearance 
                               (July 1993)

    (a) U.S. Resident Hire PSC. The contractor may commence work prior 
to the completion of the security clearance. However, until such time as 
clearance is received, the contractor shall have no access to classified 
or administratively controlled materials. Further, failure to obtain 
clearance will constitute cause for contract termination in accordance 
with paragraph (a)(2) of General Provision 16 of this contract.
    (b) U.S. PSC--Non-Resident Hire. The contractor may elect to 
commence travel to post immediately to begin work prior to completion of 
the security clearance. However, until such time as security clearance 
is received, the contractor shall:
    (1) Have no access to classified or administratively controlled 
materials;
    (2) Be authorized to travel to post himself/herself only; and
    (3) Be authorized no entitlements other than those normally 
authorized for short term (less than a year) employees at post. Even if 
the contract is for one year or more, dependents may not accompany 
contractor unless at his/her expense, and transportation/storage of 
household/personal effects and motor vehicle will not be financed by 
USAID prior to the receipt of the security clearance. Upon receipt of 
clearance, the Contracting Officer will authorize reimbursement of any 
such costs borne at contractor's expense prior to clearance provided 
they are reasonable, allocable and allowable. If appropriate given the 
length of time remaining, the Contracting Officer will authorize 
dependent travel and shipment/storage of motor vehicle and effects. 
Allowances which would not be provided to short term employees will be 
authorized after clearance is received provided that the contractor is 
otherwise entitled to such benefits. Failure to obtain the security 
clearance will constitute cause for contract termination in accordance 
with paragraph (a)(2) of General Provision 16 of this contract.

          25. Medical Evacuation (MEDEVAC) Services (July 1993)

    (a) The contractor agrees to obtain medevac service coverage for 
himself/herself

[[Page 111]]

and his/her authorized dependents while performing personal services 
abroad. Coverage shall be obtained pursuant to the terms of the contract 
between USAID and USAID's medevac service provider unless exempted in 
accordance with paragraph (b).
    (b) The following are exempted from the requirements in paragraph 
(a):
    (1) Contractors and their dependents with a health insurance program 
that includes sufficient medevac coverage as approved by the Contracting 
Officer.
    (2) Contractors and their dependents located at Missions where the 
Mission Director makes a written determination to waive the requirement 
for such coverage based on findings that the quality of local medical 
services or other circumstances obviate the need for such coverage.
    (c) Information on the current medevac service provider, including 
application procedures, is available from the Contracting Officer.

                      26. Governing Law (Nov 1996)

    This contract is established under the procurement authorities of 
the United States Government and shall be interpreted in accordance with 
the body of Federal Procurement Law in the United States. This contract 
is a complete statement of the duties, compensation, benefits, leave, 
notice, termination, and the like; therefore, the laws of the country of 
performance with respect to labor and contract matters shall not apply 
to either the carrying out of the obligations of the parties or to the 
interpretation of this agreement.

    13. FAR Clauses to be Incorporated in Full Text in Personal Services 
Contracts.
    The following FAR Clauses are always to be used along with the 
General Provisions. They are required in full text.
1. Covenant Against Contingent Fees 52.203-5
2. Electronic Funds Transfer Payment Methods 52.232-28
3. Disputes 52.233-1 (Alternate 1)
4. Preference for U.S. Flag Air Carriers 52.247-63

    14. FAR Clauses to be Incorporated by Reference in Personal Services 
Contracts
    The following FAR Clauses are to be used along with the General 
Provisions, and when appropriate, be incorporated in each personal 
services contract by reference:
1. Anti-Kickback Procedures 52.203-7
2. Limitation on Payments to Influence Certain Federal Transactions 
          52.203-12
3. Audit and Records--Negotiation 52.215-2
4. Privacy Act Notification 52.224-1
5. Privacy Act 52.224-2
6. Taxes--Foreign Cost Reimbursement Contracts 52.229-8
7. Interest 52.232-17
8. Limitation of Cost 52.232-20
9. Limitation of Funds 52.232-22
10. Assignment of Claims 52.232-23
11. Protection of Government Buildings, Equipment, and Vegetation 
          52.237-2
12. Notice of Intent to Disallow Costs 52.242-1
13. Inspection 52.246-5
14. Limitation of Liability--Services 52.246-25
[62 FR 39453, July 23, 1997]

                          Appendix E [Reserved]

    Appendix F--Use of Collaborative Assistance Method for Title XII 
                               Activities

                             1. Introduction

    This appendix provides a detailed description of the collaborative 
assistance method of contracting. This is a specialized contracting 
system which may be used for contracting with educational institutions 
eligible under, and for activities authorized under, Title XII of the 
Foreign Assistance Act of 1961, as amended, under the circumstances 
described in AIDAR 715.613-71.

                               2. Purpose

    The collaborative assistance system is designed to:
    (a) Increase the joint implementation authority and responsibility 
of the contractor and the LDC;
    (b) Encourage more effective collaboration between all participating 
parties (USAID, host country, and contractor) at important stages, 
including the design stage of a technical assistance project.

                                3. Policy

    The collaborative assistance approach represents an alternative 
method for long-term technical assistance which involves professional 
collaboration with eligible Title XII institutions and LDC counterparts 
for a problem-solving type activity to develop new institutional forms 
and capabilities, to devise operating systems and policies, and to 
conduct joint research and development--including training. In such an 
activity, the difficulty in defining, in advance, precise and 
objectively verifiable contractor inputs and long-term project content 
as a basis for payment usually requires a flexible approach to project 
design, contracting, and project implementation. Such flexibility is 
also essential to the collaborative style which is responsive to LDC 
desires in problem areas of great complexity and varying uncertainty. 
Other types of technical assistance, which are usually shorter in term 
are amenable to

[[Page 112]]

more precise definition in advance, or involve closely defined and 
relatively standardized services, or are otherwise more analogous to 
commodity resource transfers, may be suitable for other contracting 
methods, e.g., certain forms of institution building, on-the-job 
training, resource surveys, etc. The collaborative assistance method is 
an approved method for providing technical assistance when used in 
accordance with the circumstances outlined above, and with the 
guidelines set forth in paragraph 4, below.

                      4. Implementation Procedures

    (a) Introduction. This paragraph 4, provides background information, 
guidelines and procedures to effect the implementation of the policy set 
forth in paragraph 3 of this appendix.
    (b) Conditions and practices. In order for this policy to work 
effectively even when the proposed activity fits the criteria described 
under Policy, there must also be:
    (1) Acceptance of the notion that the host country, in consultation 
with the contractor, is in the best position to make tactical, day-to-
day decisions on project inputs within agreed-upon limitations and 
output expectations;
    (2) Sufficient trust and respect between the Agency and the 
contractor to allow this flexible implementation authority;
    (3) A direct-hire project monitor with appropriate background to be 
knowledgeable of progress and to assist in an advisory and facilitative 
capacity, both during and between periodic reviews. In addition, the 
following important conditions must be met:
    (i) Adequate preproject communication between, and identification of 
assistance required by, the host government and USAID;
    (ii) Full joint planning and improved project design (``Joint'' as 
used herein refers to the primary parties, i.e., the collaborating 
institutions, as well as the host government and USAID. In some 
instances, it can also include other donors.);
    (iii) Careful contractor selection, i.e., matching of the 
contractor's technical and managerial capabilities to the anticipated 
requirements of the overseas activity;
    (iv) Establishment of relationships between host country, USAID and 
contractor staff to include host country leadership, flexible 
implementation authority, and effective management by the contractor;
    (v) Improved joint project evaluation, feedback, and replanning; and
    (vi) Simplified administrative procedures and greater reliance on 
in-country logistical support.
    (c) Project Stages and Contractor Involvement. In the long-term 
technical assistance projects as described above, there are four 
discrete but sometimes overlapping decision stages which take place--
with the principal contractor usually involved in the last three.
    (1) Problem analysis and project identification. After the host 
government has indicated a desire for U.S. collaboration on a particular 
problem and the USAID field mission has determined that the proposed 
activity is consistent with its program goals and priorities, 
considerable effort is usually necessary to refine further the project 
purpose and type of assistance required and provide a basis for 
contractor selection. This is a crucial step and is focused on results 
sought--on what the prospective contractor is expected to produce in 
relation to resources to be used and to project purpose. It should 
result in a clear understanding of what the LDC wants, and an overall 
plan which includes agreement on specific objectives or outputs, 
acceptable types of activities and inputs and an initial budget--
resulting in project documentation. At this step, USAID makes decisions 
it cannot delegate on what it will support and at what cost. If needed 
to supplement its direct-hire expertise, USAID can use outside 
consultants for analysis and advice but retains the ultimate decision 
for itself in collaboration with, but independent of, the requesting 
host government. (Normally, the proposed contractor for project 
definition and subsequent implementation should not have been involved 
in the problem analysis and project identification stage as a consultant 
to either the host country government, host institution, or USAID. If a 
potential contractor has been so involved, particular care must be taken 
to prevent actual or apparent organizational conflicts of interest in 
the procurement that follows. This could require at a minimum, a careful 
assessment and complete documentation of reasons for selection.)
    Normally, there will need to be some mutual interaction between the 
overall planning stage outlined here and the detailed planning and 
design work which follows in the next phase. There will usually be some 
overlap, with preliminary decisions in this stage providing a basis for 
selection of implementing agents for stage (2) which in turn proceeds 
through some preliminary planning to guide completion of stage (1) as a 
basis for long-term contracting.
    (2) Project definition. At this stage, having selected the 
implementing agent, the U.S. and LDC organizations which will be 
collaborating in carrying out the project are encouraged to work out, to 
their mutual \3/8\satisfaction, the particulars of what to do and how to 
do it (i.e., detailed project design) within the context of LDC 
leadership and responsibility and the general agreements and budget 
reached in stage (1). The emphasis here is on the technical approach to 
be utilized and the scheduling and management of project inputs. This 
may involve a short-term reconnaissance and/or an extensive period of 
detailed joint planning and feeling out of what is feasible during a 
preliminary

[[Page 113]]

operating phase of the project, possibly lasting as much as a year or 
more. This stage recognizes the importance, for the problem-solving or 
ground breaking types of technical assistance, of involving the U.S. and 
LDC implementing organizations together as soon as the detailed design 
work begins. USAID's role here is to facilitate, not direct, the joint 
planning, assure consistency with prior agreements or concur in changes, 
affirm that the implementing parties have agreed on a reasonable project 
design, and prepare or cause to be prepared the documentation required 
for stage (3), including any amendments that might be required to the 
project documentation. If and when a decision is made by the host 
government and USAID to proceed into the operating phase with the same 
contractor, the U.S. intermediary should be treated as a cooperating 
partner in the negotiation of the subsequent long-term operating 
agreement(s) with the host government, host institution and USAID.
    (3) Implementation. The results of the approach outlined in the 
stage above should include, in addition to a better understanding and 
more meaningful commitment by all parties, the following specific 
products:
    (i) A jointly developed life-of-project design which reflects the 
commitment of all parties and includes clear statements of purpose, 
principal outputs, eligible types of activity and expenditure limits, 
critical assumptions, and major progress indicators;
    (ii) A workplan and input schedule for the first two years or at 
least as long as the expenditure period for the next obligation of 
project funds;
    (iii) Provisions for any administrative support, special services or 
other inputs by the host country, contractor, and/or USAID; and
    (iv) A plan for periodic joint evaluation and review or progress and 
subsequent workplans, normally annually, with the participation of all 
parties.
    Appropriate elements of these agreements and understandings are now 
embodied in a contract for project implementation, as described in 
paragraph (d)(3)(i) of the section on Contracting Implications. This 
contract allows the U.S. intermediary to apply its judgment, reflecting 
close collaboration with its LDC colleagues, in adjusting the flow of 
USAID-financed inputs and in making other operational decisions with a 
minimum of requirements for prior USAID approvals or contract amendments 
as long as the contractor stays within the bounds of the approved 
overall plan and budget. In this phase, USAID will give technical 
assistance contractors the authority and responsibility for using their 
specialized expertise to the fullest extent in the scheduling and 
managing of project inputs.
    (4) Monitoring, joint evaluation and replanning. With increased 
flexibility and responsibility for implementation placed with the 
technical assistance contractor, the host government, and/or 
institutional collaborator, improved and timely progress reporting and 
periodic, joint, and structured reviews of results and evolving plans 
are imperative as a basis for monitoring and evaluating contractor 
performance, revalidating or adjusting project design, and for 
determining future funding levels and commitments.
    Both the contractor's annual report and the joint review should be 
structured within the framework of purpose, outputs, performance 
indicators, etc., originally established in the project indentification 
phase--as modified by detailed project design--and reflected in the 
Project Agreement and other pertinent documentation. The field review 
will normally serve as the occasion for discussing changes in or 
additions to previously agreed-to workplans as well as proposing changes 
in purpose, types of activities authorized and budgets which require 
contract amendment. Obviously, the appropriate host government, host 
institution, and senior contractor officials should be thoroughly 
involved in the process, which will have to be adapted to the conditions 
within specific projects and countries. An important USAID 
responsibility is to assure that there is appropriate host country 
participation in developing and improving project plans prior to new 
obligations of funds. The special requirements and responsibilities of 
the various parties shall also be reflected in the project agreement and 
contract terms and in guidelines on the content of annual reports, 
evaluation procedures, etc.
    Standard checking on services actually delivered as a basis for 
reimbursement will be continued including appropriate audit of 
expenditures.
    (d) Contracting implications. The principal elements of change in 
present contracting practices, as detailed below, are earlier selection 
and involvement of the prime contractor, contracting by major stages of 
project design and operations, minimizing the need for precontract 
negotiations and contract amendments and USAID approvals, and providing 
technical assistance contractors with the authority and responsibility 
needed to manage implementation within the approved program bounds.
    (1) Selection. The early involvement of the contractor in the 
definition stage of a long-term technical assistance project, after 
USAID decides what it wants to undertake in stage (1), does not alter 
the Agency's responsibility to select its contractors carefully and in 
full compliance with appropriate contracting regulations and selection 
procedures. What is required here is that contractor selection be 
carried out at an earlier stage than has sometimes been the Agency 
practice in the past or with other types of

[[Page 114]]

contracts and in anticipation that the contractor, assuming adequate 
performance, will participate in all subsequent phases until final 
completion.
    (2) Contracting stages. In contracting, the initial design stage 
should be separated from the longer term implementation stage without 
any USAID commitment to undertake the second until it has exercised its 
independent judgment based on the product of the first plus any outside 
expert appraisal it and the host country want to use.
    The long-term implementation stage itself may be further subdivided 
into contract periods which permit time between predetermined events for 
analysis, determination of new project requirements, and evaluation of 
performance prior to initiating the next phase by contract amendment/
extension. If, for any reason, such an examination does not appear to 
warrant project continuation, then termination of the project and/or 
contract would be the next step.
    (3) Flexible implementation authority. While good project design 
will eliminate or diminish many operational problems, the very nature of 
long-term technical assistance requires flexible implementation within 
agreed purposes, ultimate outputs, types of activity and available 
financing. With these key variables for USAID management control 
established, contracts should be written so as to minimize the need for 
amendments and USAID approval of changes in input particulars. This can 
be facilitated, both for the USAID, host country, institution, and the 
contractor by:
    (i) Retention of operational plan in contract and removal of 
workplan. The contract narrative will contain the life-of-the-project 
Operational Plan, consistent with the project design as developed in 
stage (2) and reflected in the project documentation (and subsequent 
amendments thereto). The Operational Plan includes a statement of the 
purpose to be achieved, the outputs to be produced by the contractor and 
the types of activities to be undertaken, the more significant 
indicators of progress, a general description of the type of inputs that 
are authorized and intended to be provided during the life of the 
project, and the overall budget.
    In order to allow adjustments at the implementation level without 
going through the contract amendment process, the detailed but short-
term workplan containing specific descriptions and scheduling of all 
inputs such as numbers and types of staff, participants, commodities, 
etc., and specific activities, will not be a part of the contract. It is 
a working document to be modified in the field when the situation 
demands. The latest version will be available as a supporting document 
to justify proposed new obligation levels. Normally, the workplan and 
derived budget will cover a rolling two year period, i.e., each year 
another yearly increment is added after review and approval.
    (ii) Budget flexibility. To support this implementation flexibility, 
contract budget or fiscal controls will be shifted from fixed line items 
for each input category to program categories, permitting the technical 
assistance contractor to adjust amounts and timing to achieve previously 
approved types of activity. This same type of flexibility should apply 
to any local currency supplied for project operations and/or contractor 
staff support. While an essential corollary to eliminating the workplan 
from the contract, this is not a unique procedure under cost 
reimbursement type contracts when the contractor has demonstrated 
adequate management capability.
    (iii) Negotiation of advance understandings. To permit university 
and international research center contractors to manage their activities 
in accordance with their own policies and procedures and thereby sharpen 
their management responsibility while achieving substantial savings in 
time and reduced documentation, USAID may negotiate advance 
understandings with its technical assistance contractors on dollar costs 
and administrative procedures that would be included by reference in its 
subsequent contracts. Upon receipt of a request from the contractor that 
their policies be reviewed and approved for usage in their contract in 
lieu of the standard terms and conditions, OP/PS/OCC, USAID/W will 
initiate negotiations of such policies in an expeditious manner. The 
approved policies will be used in all relevant relations involving the 
Agency and respective contractors in lieu of traditional contract 
standard provisions, whenever this may be appropriate. This does not 
apply to local currency costs and host government procedures which must 
be negotiated in each case.
    The purpose of the practices listed above is not only to give a 
qualified contractor the authority to adjust the composition and timing 
of inputs but to assign to it clear responsibility for managing such 
resources, as the evolving circumstances require, to achieve the agreed-
upon outputs on a cost efficient basis. It should also reduce the delay 
and paperwork involved in frequent but minor contract amendments, and 
approvals. For the agency as a whole, both in the Mission and in USAID/
W, these have involved a large workload and cost.
    (e) Role of USAID. Nothing in this appendix is intended to delegate, 
diminish or otherwise modify USAID's final responsibility for the 
prudent management of public funds and its own programs. Rather in 
withdrawing from the day-to-day involvement in and responsibility for 
the management of adjustment of the flow of inputs during the 
implementation, the best use of limited agency staff and time can be 
devoted to protecting

[[Page 115]]

the public interest in gaining maximum results from the funds 
appropriated for technical assistance by:
    (1) Seeking optimum identification in terms of LDC priorities and 
U.S. capabilities;
    (2) Mobilizing and selecting the best U.S. professional talent to 
design and carry out the project;
    (3) Monitoring what is happening to assure adequacy of processes, 
get a feel of results, assure actual delivery of inputs being financed;
    (4) Assuring that the attention of USAID's implementation agents and 
LDC colleagues stay well focused on project purpose and results to be 
achieved (outputs) and the relation to these of what is being done and 
actual results;
    (5) Providing intermediaries adequate authority and responsibility 
to adjust inputs promptly and sensitively to the evolving project 
situations.
    Attention to these considerations, and to achievements of the 
preimplementation conditions prescribed above, should greatly increase 
the chances for successful project completion and impact on a cost 
effective basis, which is the final measurement of prudent management.

  Attachment to Appendix F--Guidelines for Requests for Expressions of 
                                Interest

                      A. Length and Level of Detail

    A Request for Expression of Interest (REI) should include more than 
just a short letter expressing interest, but should not be in the detail 
of a technical proposal (RFTP). The REI is not the only source of 
information that can or should be used for selection, but at least a 
minimum level of information should be contained in each document. A ten 
page paper that responds to the selection criteria included in every REI 
should be sufficient for evaluation purposes. The selection criteria 
should specify the technical inputs required for successful execution of 
the project and normally require a response in three general areas:
    1. A description of the institution's capability to address the 
problem described in the REI.
    2. Any related experience, whether in the country or region or in 
the problem area.
    3. A demonstrable commitment of the institution to support the 
project.
    The responses should address the capability, experience, and 
commitment to the particular project.

                    B. Specific Personnel Information

    The response should specify within the areas set out in the 
selection criteria the following planning and personnel factors.
    1. The design team plan and the scope of work for each member.
    2. A list of candidates for the design team and their credentials.
    3. A list of possible candidates for long-term assignment to the 
project. (Since there has been no project design, the specific technical 
assistance slots and technical responsibilities are vague. But it is 
expected that at least half of the personnel needs can be estimated 
early in the project. The institution should make its best guess for the 
team and present to the Agency the persons or types of persons with whom 
they are likely to contract.)

                   C. Multiple Institution Submissions

    Joint effort on the part of several institutions is encouraged when 
appropriate. A single institution may submit an expression of interest 
for part of the project without knowledge of other collaborators or it 
may submit information in response to A and B of this attachment as part 
of a suggested collection of institutions. In either case, a proposed 
plan for cooperation is necessary.
    However, such joint efforts must specify the division of 
responsibilities for the planning and personnel factors indicated in B 
of this attachment. Often USAID will identify the need for cooperation 
and suggest such an effort in the REI. Even if USAID does not suggest 
collaboration, joint efforts with a description of the cooperation would 
be an appropriate way to respond to an REI.

(Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) as amended; 
E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., p. 435)
[49 FR 13301, Apr. 3, 1984, as amended at 49 FR 33669, Aug. 24, 1984; 50 
FR 16089, Apr. 24, 1985; 51 FR 20652, June 6, 1986; 52 FR 6160, Mar. 2, 
1987]

                          Appendix G [Reserved]

                          Appendix H [Reserved]

             Appendix I--USAID's Academic Publication Policy

                         1. Statement of Policy

    This is a statement of USAID policy on publication, or release to 
parties other than those specifically authorized, of unclassified 
materials gathered or developed under contracts with academic 
institutions.

                        2. Underlying Principles

    USAID favors and encourages the publication of scholarly research as 
well as the maximum availability, distribution, and use of knowledge 
developed in its program.
    This policy statement does not deal with material that is classified 
for security reasons. It does deal with considerations of national 
interest, not of sufficient gravity to warrant security classification, 
but serious

[[Page 116]]

enough to affect adversely the conduct of U.S. assistance programs. 
Consequently, in addition to the requirements of courtesy, propriety, 
and confidence which normally guide scholars in their work, there should 
also be consideration of the potential repercussions of publication on 
the successful execution of development and other cooperative programs 
in which the United States and foreign countries are involved.

                       3. Operational Definitions

    The Agency draws a distinction between two kinds of manuscripts 
which a scholar may wish to publish:
    (a) A report which is prepared and delivered to the Agency under the 
terms of the contract (a ``contract manuscript''); and
    (b) An article or book based upon experience and information gained 
under an USAID contract but not prepared or delivered under the contract 
(a ``non-contract manuscript'').
    There are two kinds of actions, to be specified in the contract, 
which the Agency can take upon notification of a contractor's desire to 
publish:
    (a) Comment only, under which USAID and the foreign government 
involved may review the manuscript, and have their comments considered 
seriously by the contractor prior to publication; and
    (b) Authorization for release, which USAID may withhold if 
reconciliation between the national interest and the author's interest 
is impossible.

                          4. Policy Statements

    (a) USAID, as a general rule, will not require an academic 
institution to obtain permission to publish the written work produced 
under a contract. It will ask for the opportunity to review the 
manuscript for comment only, prior to publication.
    In the case of a contract manuscript, USAID reserves the right to 
disclaim endorsement of the opinions expressed; if it is a noncontract 
manuscript, USAID reserves the right to disassociate itself from 
sponsorship or publication.
    (b) On the other hand, USAID may reserve the right of authorization 
for release in those exceptional cases where conditions exist making it 
reasonably foreseeable, in light of the contract's scope of work and the 
manner and place of performance, that the written work to be prepared 
and delivered under the contract may have adverse repercussions on the 
relations and programs of the United States. Where this right is 
reserved, it must be so specified in the contract. In determining where 
to reserve such right, USAID will consider all relevant factors, 
including:
    (1) The extent to which prompt and full performance of the contract 
will require access, facilitated by reason of the contract, to 
information not generally available to scholars;
    (2) The extent to which the work involves matters of political 
concern to foreign countries, particularly where any substantial part of 
the work is to be performed therein;
    (3) The extent to which, by reason of USAID's close involvement and 
cooperation in the performance of the contract, the work product may be 
so identified with USAID itself as to prevent effective disclaimer of 
USAID endorsement thereof;
    (4) The extent to which the objective of the contract is to provide 
advice to USAID or to a foreign government of immediate operational 
significance in the conduct of the USAID program or the implementation 
of governmental programs in the host country;
    (5) The desires of the host country.

                            5. Implementation

    The successful implementation of this policy on publication rests on 
a thorough understanding and acceptance of these principles by USAID and 
the prospective contractor. The actual publications provision for a 
particular contract, then, would be so worded as to reflect the 
agreement reached in the contract negotations.
    USAID's concern with noncontract manuscripts is related to the 
identification of a manuscript with the U.S. Government. This concern 
will be modified by the passage of time following termination of the 
contract.
    In the normal case of prepublication review for USAID comment, the 
institution will submit a copy of the manuscript not later than the date 
of submission to the publisher. This gives the Agency time to comment if 
it is deemed appropriate. However, in the case of review for 
authorization, timely notification of USAID's response will be given, 
consistent with the size of the manuscript and the number and location 
of the parties involved.
    The Agency will make every effort to expedite this review procedure 
in accordance with the underlying principle described at the beginning 
of this policy statement.

(Sec. 621, Pub. L. 87-195, 75 Stat. 445, (22 U.S.C. 2381) as amended; 
E.O. 12163, Sept. 29, 1979, 44 FR 56673; 3 CFR, 1979 Comp., p. 435)
[49 FR 13304, Apr. 3, 1984]

 Appendix J--Direct USAID Contracts With a Cooperating Country National 
     and With a Third Country National for Personal Services Abroad

                               1. General

    (a) Purpose. This appendix sets forth the authority, policy, and 
procedures under which USAID contracts with cooperating

[[Page 117]]

country nationals or third country nationals for personal services 
abroad.
    (b) Definitions. For the purpose of this appendix:
    (1) Personal services contract (PSC) means a contract that, by its 
express terms or as administered, make the contractor personnel appear, 
in effect, Government employees (see FAR 37.104).
    (2) Employer-employee relationship means an employment relationship 
under a service contract with an individual which occurs when, as a 
result of (i) the contract's terms or (ii) the manner of its 
administration during performance, the contractor is subject to the 
relatively continuous supervision and control of a Government officer or 
employee.
    (3) Non-personal services contract means a contract under which the 
personnel rendering the services are not subject either by the 
contract's terms or by the manner of its administration, to the 
supervision and control usually prevailing in relationships between the 
Government and its employees.
    (4) Independent contractor relationship means a contract 
relationship in which the contractor is not subject to the supervision 
and control prevailing in relationships between the Government and its 
employees. Under these relationships, the Government does not normally 
supervise the performance of the work, or the manner in which it is to 
be performed, control the days of the week or hours of the day in which 
it is to be performed, or the location of performance.
    (5) Contractor means a cooperating country national or a third 
country national who has entered into a contract pursuant to this 
appendix.
    (6) Cooperating country means the country in which the employing 
USAID Mission is located.
    (7) Cooperating country national (CCN) means an individual who is a 
cooperating country citizen or a non-cooperating country citizen 
lawfully admitted for permanent residence in the cooperating country.
    (8) Third Country National (TCN) means an individual
    (i) Who is neither a citizen nor a permanent legal resident alien of 
the United States nor of the country to which assigned for duty, and
    (ii) Who is eligible for return to his/her home country or country 
of recruitment at U.S. Government expense [see Section 12, General 
Provision 9 paragraph (n)].

                             2. Legal Basis

    (a) Section 635(b) of the Foreign Assistance Act of 1961, as 
amended, hereinafter referred to as the ``FAA'', provides the Agency's 
contracting authority.
    (b) Section 636(a)(3) of the FAA authorizes the Agency to enter into 
personal services contracts with individuals for personal services 
abroad and provides further that such individuals ``* * * shall not be 
regarded as employees of the U.S. Government for the purpose of any law 
administered by the Civil Service Commission.''\1\
---------------------------------------------------------------------------

    \1\The Civil Service Commission is now the Federal Office of 
Personnel Management.
---------------------------------------------------------------------------

                            3. Applicability

    (a) This appendix applies to all personal services contracts with 
CCNs or TCNs to provide assistance abroad under Section 636(a)(3) of the 
FAA.
    (b) This appendix does not apply to:
    (1) Contracts for non-personal services with TCNs or CCNs; such 
contracts are covered by the basic text of the FAR and AIDAR.
    (2) Personal services contracts with U.S. citizens or U.S. resident 
aliens for personal services abroad; such contracts are covered by 
Appendix D of this chapter.
    (3) Appointments of experts and consultants as USAID direct-hire 
employees; such appointments are covered by USAID Handbook 25, 
Employment and Promotion or superseding Chapters of the Automated 
Directive System (ADS).

                                 Policy

    (a) General. USAID may finance, with either program or operating 
expense (OE) funds, the cost of personal services as part of the 
Agency's program of foreign assistance by entering into a direct 
contract with a CCN or a TCN for personal services abroad.
    (1) Program funds. Under the authority of Section 636(h) of the FAA, 
program funds may be obligated for periods up to five years where 
necessary and appropriate to the accomplishment of the tasks involved.
    (2) Operating expense funds. Pursuant to USAID budget policy, OE 
funded salaries and other recurrent cost items may be forward funded for 
a period of up to three (3) months beyond the fiscal year in which these 
funds were obligated. Non-recurring cost items may be forward funded for 
periods not to exceed twenty-four (24) months where necessary and 
appropriate to accomplishment of the work.\2\
---------------------------------------------------------------------------

    \2\If there is a need, these contracts may be written for 5 years 
but only funded as outlined above.
---------------------------------------------------------------------------

    (b) Limitations on Personal Services Contracts.
    (1) Personal services contracts may only be used when adequate 
supervision is available.
    (2) Personal services contracts may be used for commercial 
activities. Commercial activities provide a product or service which 
could be obtained from a commercial source. See Attachment A of OMB 
Circular A-76 for a representative list of such activities.

[[Page 118]]

    (3) Notwithstanding any other provision of USAID directives, 
regulations or delegations, Cooperating Country or Third Country 
Nationals may be delegated or assigned any authority, duty or 
responsibility, delegated or assigned U.S. citizen direct-hire employees 
(USDH employees) except that:
    a. They may not supervise USDH employees of USAID or other U.S. 
Government agencies. They may supervise USPSCs and non-U.S. citizen 
employees.
    b. They may not be designated a Contracting Officer or delegated 
authority to sign obligating or subobligating documents.
    c. They may represent the agency, except that communications that 
reflect a final policy, planning or budget decision of the agency must 
be cleared by a USDH employee.
    d. They may participate in personnel selection matters but may not 
be delegated authority to make a final decision on personnel selection.
    e. Services which involve security classified material.
    (4) Exceptions. Exceptions to the limitations in (b)(3) must be 
approved by the Assistant Administrator for Management (AA/M).
    (c) Conditions of Employment.
    (1) General. For the purpose of any law administered by the U.S. 
Office of Personnel Management, USAID PSC contractors are not to be 
regarded as employees of the U.S. Government, are not included under any 
retirement or pension program of the U.S. Government, and are not 
eligible for the Incentive Awards Program covered by Uniform State/
USAID/USIA regulations. Each USAID Mission is expected to participate in 
the Joint Special Embassy Incentive Awards Program. The program is 
administered by a joint committee which establishes procedures for 
submission, review and approval of proposed awards. Other than these 
exceptions, CCNs and TCNs who are hired for work in a cooperating 
country under PSCs generally will be extended the same benefits and be 
subject to the same restrictions as Foreign Service Nationals (FSNs) 
employed as direct-hires by the USAID Mission.
    (2) Compensation. (i) It is USAID's general policy (see AIDAR 
722.170) that PSC compensation may not, without the approval of the 
Mission Director or Assistant Administrator, exceed the prevailing 
compensation paid to personnel performing comparable work in the 
cooperating country. Compensation for TCN or CCN personal services 
contractors set in accordance with the provisions of 4c(2)(ii) below 
satisfies this requirement.
    (ii) In accordance with Section 408(a)(1) of the Foreign Service Act 
of 1980, a local compensation plan forms the basis for all compensation 
payments to FSNs which includes CCNs and TCNs. The plan is each post's 
official system of position classification and pay, consisting of the 
local salary schedule which includes salary rates, statements 
authorizing fringe benefit payments, and other pertinent facets of 
compensation for TCNs and CCNs, and the local position classification 
system as reflected in the Local Employee Position Classification 
Handbook (LEPCH) or equivalent in effect at the Mission. Compensation 
for PSCs will be in accordance with the local compensation plan, to the 
extent that it covers employees of the type or category being employed, 
unless the Mission Director determines otherwise. If the Mission 
Director determines that compensation in accordance with the local plan 
would be inappropriate in a particular instance, then compensation will 
be set in accordance with (in order of preference):
    (A) Any other Mission policies on foreign national employee 
compensation; or
    (B) Paragraphs 4(c) (d), (e), (g), (h), and (i) of Appendix D. When 
compensation is set in accordance with this exception, the record shall 
be documented in writing with a justification prepared by the requesting 
office and approved by the Mission Director.
    (iii) The earning of leave (annual and sick), allowances and 
differential (if applicable), salaries and all other related benefits 
cannot be enumerated in this Appendix as they vary from Mission to 
Mission and are based upon the compensation plan for each.
    (iv) Unless otherwise authorized, the currency in which compensation 
is paid to contractors shall be in accordance with the prevailing local 
compensation practice of the post.
    (v) CCN and TCN contractors are eligible for allowances and 
differential on the same basis as direct-hire FSN employees under the 
post compensation plan.
    (vi) A USAID PSC who is a spouse of a current or retired U.S. Civil 
Service, U.S. Foreign Service, or U.S. military service member, and who 
is covered by their spouse's government health or life insurance policy, 
is ineligible for a contribution towards the costs of annual health and 
life insurance.
    (vii) Retired CCNs and TCNs may be awarded personal services 
contracts without any reduction in or offset against their Government 
annuity.
    (3) Incentives Awards. (i) All Cooperating Country Nationals direct-
hire and Personal Services Contractors (PSCs) and Third Country 
Nationals (PSCs) of the Foreign Affairs Community are eligible for the 
Joint Special Embassy Incentive Awards Program.
    (ii) Meritorious Step Increases for USAID FSN PSCs may be authorized 
provided the granting of such increases is the general practice locally.
    (iii) The Joint Country Awards Committee administers each post's 
(Embassy) award program, including establishment of procedures for 
submission, review and approval of proposed awards.

[[Page 119]]

    (4) Training. CCN and TCN PSCs are eligible for most of the training 
courses offered in the Training Course Schedule. However, applications 
will be processed on a case-by-case basis and are required to be 
approved by the Contracting Officer.

              5. Soliciting for Personal Services Contracts

    (a) Technical Officer's Responsibilities. The Technical Officer will 
prepare a written detailed statement of duties and a statement of 
minimum qualifications to cover the position being recruited for; the 
statement shall be included in the procurement request. The procurement 
request shall also include the following additional information as a 
minimum:
    (1) The specific foreign location(s) where the work is to be 
performed, including any travel requirements (with an estimate of 
frequency);
    (2) The length of the contract, with beginning and ending dates, 
plus any options for renewal or extension;
    (3) The basic education, training, experience, and skills required 
for the position;
    (4) A certification from the officer in the Mission responsible for 
the LEPCH or equivalent that the position has been reviewed and is 
properly classified as to a title, series and grade in accordance with 
the LEPCH. If the position does not fall within the LEPCH or equivalent 
system, and estimate of compensation based on subparagraphs 4(c)(2)(ii) 
(A) or (B) of this Appendix after consultations or in coordination with 
the contract officer or executive officer;
    (5) A list of Government or host country furnished items (e.g., 
housing).
    (b) Contracting Officer's Responsibilities. (1) The Contracting 
Officer will prepare the solicitation for personal services which shall 
contain:
    (i) Three sets of certified biographical data and salary history. 
(Upon receipt, one copy of the above information shall be forwarded to 
the Project Officer);
    (ii) A detailed statement of duties or a completed position 
description for the position being recruited for;
    (iii) A copy of the prescribed contract Cover Page, Contract 
Schedule, and General Provisions as well as the FAR Clause to be 
included in full text and a list of those to be incorporated by 
reference; and
    (iv) A copy of General Notice entitled ``Employee Review of the New 
Standards of Conduct'' dated October 30, 1992.
    (2) The Contracting Officer shall comply with the limitations of 
AIDAR 706.302-70(c) as detailed in paragraph 5(c) below.
    (c) Competition. (1) Under AIDAR 706.302-70(b)(1), Personal Services 
Contracts are exempt from the requirements for full and open competition 
with two limitations that must be observed by Contracting Officers:
    (i) Offers are to be requested from as many potential offerors as is 
practicable under the circumstances, and
    (ii) a justification supporting less than full and open competition 
must be prepared in accordance with FAR 6.303.
    (2) A class justification was approved by the USAID Procurement 
Executive to satisfy the requirements of AIDAR 706.302-70(c)(2) for a 
justification in accordance with FAR 6.303. Use of this class 
justification for Personal Services Contracts with Cooperating Country 
Nationals and Third Country Nationals is subject to the following 
conditions:
    (i) New contracts are publicized consistent with Mission/Embassy 
practice on announcement of direct hire FSN positions. Renewals or 
extensions with the same individual for continuing service do not need 
to be publicized.
    (ii) A copy of the class justification (which was distributed to all 
USAID Contracting Officers via Contract Information Bulletin) must be 
included in the contract file, together with a written statement, signed 
by the Contracting Officer, that the contract is being awarded pursuant 
to AIDAR 706.302-70(b)(1); that the conditions for use of this class 
justification have been met; and that the cost of the contract is fair 
and reasonable. If the conditions in paragraphs (2)(i) and (ii) are not 
followed, the Contracting Officer must prepare a separate justification 
as required under AIDAR 706.302-70(c)(2).
    (3) Since the award of a personal services contract is based on 
technical qualifications, not price, and since the biographical data and 
salary history are used to solicit for such contracts, FAR Subparts 15.4 
and 15.5 are inappropriate and shall not be used. Instead, the 
solicitation and selection procedures outlined in this Appendix shall 
govern.

               6. Negotiating a Personal Services Contract

    Negotiating a Personal Services Contract is significantly different 
from negotiating a nonpersonal services contract because it establishes 
an employer-employee relationship; therefore, the selection and 
negotiations procedures are more akin to the personal selection 
procedures.
    (a) Technical Officer's Responsibilities. The Technical Officer 
shall be responsible for reviewing and evaluating the applications 
received in response to the solicitation issued by the Contracting 
Officer. If deemed appropriate, interviews may be conducted with the 
applicants before the final selection is submitted to the Contracting 
Officer.
    (b) Contracting Officer's Responsibilities.
    (1) The Contracting Officer shall forward a copy of biographical 
data and salary history received under the solicitation to the Technical 
Officer for evaluation.
    (2) On receipt of the Technical Officer's recommendation, the 
Contracting Officer

[[Page 120]]

shall conduct negotiations with the recommended applicant. The terms and 
conditions of the contract will normally be in accordance with the local 
compensation plan which forms the basis for all compensation on payments 
paid to FSNs which includes CCNs and TCNs.
    (3) The Contracting Officer shall use the certified salary history 
on the certified statement of biographical data and salary history as 
the basis for salary negotiations, along with the Technical Officer's 
cost estimate.
    (4) The Contracting Officer will obtain necessary data for a 
security and suitability clearance to the extent required by USAID 
Handbook 6, Security or superseding ADS Chapters.

                7. Executing a Personal Services Contract

    Contracting activities, whether USAID/W or Mission, may execute 
Personal Services Contracts, provided that the amount of the contract 
does not exceed the contracting authority that has been redelegated to 
them. See AIDAR 701.601. In executing a personal service contract, the 
Contracting Officer is responsible for insuring that:
    (a) The proposed contract is within his/her delegated authority;
    (b) A written detailed statement of duties covering the proposed 
contract has been received;
    (c) The proposed scope of work is contractible, contains a statement 
of minimum qualifications from the technical office requesting the 
services, and is suitable for a personal services contract in that:
    (1) Performance of the proposed work requires or is best suited for 
an employer-employee relationship, and is thus not suited to the use of 
a non-personal services contract;
    (2) The scope of work does not require performance of any function 
normally reserved for direct-hire Federal employees (under paragraph 
4(b) of this Appendix); and
    (3) There is no apparent conflict of interest involved (if the 
Contracting Officer believes that a conflict of interest may exist, the 
question should be referred to the cognizant legal counsel);
    (d) Selection of the contractor is documented and justified (AIDAR 
706.302-70(b)(1) provides an exception to the requirement for full and 
open competition for Personal Services Contracts abroad; see paragraph 
5(c) of this Appendix);
    (e) The standard contract format prescribed for a Cooperating 
Country National and a Third Country National personal services contract 
(Sections 9, 10, 11, 12, and 13 of this Appendix as appropriate) is 
used, or that any necessary deviations are processed as required by 
AIDAR 701.470;
    (f) The contractor has submitted the names, addresses, and telephone 
numbers of at least two persons who may be notified in the event of an 
emergency (this information is to be retained in the contract file);
    (g) The contract is complete and correct and all information 
required on the contract Cover Page (USAID form 1420-36B) has been 
entered;
    (h) The contract has been signed by the Contracting Officer and the 
contractor, and fully executed copies are properly distributed;
    (i) The following clearances, approvals and forms have been 
obtained, properly completed, and placed in the contract file before the 
contract is signed by both parties:
    (1) Security clearance to the extent required by USAID Handbook 6, 
Security or other superseding Chapters of the Automated Directives 
System;
    (2) Mission, host country, and technical office clearance, as 
appropriate;
    (3) Medical clearance(s) based on a full medical examination(s) and 
statement of medical opinion by a licensed physician. The physician's 
medical opinion must be in the possession of the Contracting Officer 
prior to signature of contract. If a TCN is recruited, medical clearance 
requirements apply to the contractor and each dependent who is 
authorized to accompany the contractor;
    (4) The approval for any salary in excess of ES-6, in accordance 
with Appendix G of this chapter;
    (5) A copy of the class justification or other appropriate 
explanation and support required by AIDAR 706.302-70, if applicable;
    (6) Any deviation to the policy or procedures of this Appendix, 
processed and approved under AIDAR 701.470;
    (7) The memorandum of negotiation;
    (j) The position description is classified in accordance with the 
LEPCH, and the proposed salary is consistent with the local compensation 
plan or the alternate procedures established in 4(c)(2)(ii) above;
    (k) Funds for the contract are properly obligated to preclude 
violation of the Anti-Deficiency Act, 31 U.S.C. 134 (the Contracting 
Officer ensures that the contract has been properly recorded by the 
appropriate accounting office prior to its release for the signature of 
the selected contractor);
    (l) The contractor receives and understands USAID General Notice 
entitled ``Employee Review of the New Standards of Conduct'' dated 
October 30, 1992 and a copy is attached to each contract, as provided 
for in paragraph (c) of General Provision 2, Section 12;
    (m) Agency conflict of interest requirements, as set out in the 
above notice are also met by the contractor prior to his/her reporting 
for duty;
    (n) A copy of a Checklist for Personal Services Contractors which 
may be in the form set out above or another form convenient for the 
contracting officer, provided that a form containing all of the 
information described

[[Page 121]]

in this paragraph 7 shall be prepared for each PSC and placed in the 
contract file;
    (o) In consultation with the regional legal advisor and/or the 
regional contracting officer, the contract is modified by deleting from 
the General Provisions (Sections 12 and 13 of this Appendix) the 
inapplicable clause(s) by a listing in the Schedule; and
    (p) The block entitled, ``Acquisition and Assistance Request 
Document'' on the Cover Page of the contract format is completed by 
inserting the four-segment technical number as prescribed in USAID 
Handbook 18, the USAID Code Book Appendix D or superseding ADS Chapter 
if the PSC is project-funded.

                          8. Contracting Format

    The prescribed Contract Cover Page, Contract Schedules, General 
Provisions and FAR Clauses for personal service contracts for TCNs and 
CCNs covered by this Appendix are included as follows:
    9. ``Cover Page'' for a Contract with a Cooperating Country National 
or with a Third Country National for Personal Services.
    10. ``Schedule'' for a Contract with a Cooperating Country National 
or Third Country National Personal Services Contracts.
    11. ``Optional Schedule'' for a Contract with a Cooperating Country 
National or Third Country National Personal Services Contracts.
    [Use of the Optional Schedule is intended to serve as an alternate 
procedure for OE funded Foreign Service National PSCs. The schedule was 
developed for use when the Contracting Officer anticipates incremental 
recurring cost funded contracts. It should be noted that the Optional 
Schedule eliminates the need to amend the contract each time funds are 
obligated. However, the Contracting Officer is required to amend each 
contract not less than twice during a 12 month period to ensure that the 
contract record of obligations is up to date and agrees with the figures 
in the master funding document.]
    12. ``General Provisions'' for a Contract With a Cooperating Country 
National or With a Third Country National for Personal Services.
    13. FAR Clauses to be incorporated in full text as well as by 
reference in Personal Services Contracts.

9. ``Cover page'' for a Contract With a Cooperating Country National or 
          With a Third Country National for Personal Services.

    --AID Form 1420-36B (11/96)

[[Page 122]]

[GRAPHIC] [TIFF OMITTED] TR11AU97.005



 10. ``Schedule'' for a Contract With a Cooperating Country National or 
           Third Country National Personal Services Contracts

Contract No.______
Table of Contents
    The Schedule on pages ______ through ______ consists of this Table 
of Contents, the following Articles, and General Provisions:
Article I  Statement of Duties

[[Page 123]]

Article II  Period of Service
Article III  Contractor's Compensation and Reimbursement
Article IV  Costs Reimbursable and Logistic Support
Article V  Precontract Expenses
Article VI  Additional Clauses

General Provisions

    The following provisions, numbered as shown below, omitting 
number(s) ______, are the General Provisions (GPs) of this Contract:

1. Definitions
2. Compliance with Applicable Laws and Regulations
3. Physical Fitness
4. Security
5. Workweek
6 Leave and Holidays
7. Social Security and Cooperating Country Taxes
8. Insurance
9. Travel and Transportation
10. Payment
11. Contractor-Mission Relationships
12. Termination
13. Allowances
14. Advance of Dollar Funds
15. Conversion of U.S. Dollars to Local Currency
16. Post of assignment Privileges
17. Release of Information
18. Notices
19. Incentive Awards
20. Training
21. Medical Evacuation Services

    Schedule

    Note: Use of the following Schedule is not mandatory.

    The Schedule is intended to serve as a guideline and as a checklist 
for contracting offices in drafting contract schedules. Article language 
shall be changed to suit the needs of the particular contract. Special 
attention should be given to the financial planning sections where 
unnecessary line items should be eliminated.

                     Article I--Statement of Duties

    [The statement of duties shall include:
    A. General statement of the purpose of the contract.
    B. Statement of duties to be performed.
    C. Orientation or training to be provided by USAID.]

                      Article II--Period of Service

    Within ______ days after written notice from the Contracting Officer 
that all clearances, including the statement of medical opinion required 
under General Provision Clause 3, have been received, unless another 
date is specified by the contracting officer in writing, the contractor 
shall proceed to ______ and shall promptly commence performance of the 
duties specified above. The contractor's period of service shall be 
approximately ______ in ______. (Specify time of duties in each 
location.)

        Article III--Contractor's Compensation and Reimbursement

    A. Except as reimbursement may be specifically authorized by the 
Mission Director or contracting officer, USAID shall pay the contractor 
compensation after it has accrued and make reimbursements, if any are 
due, in currency of the post or for necessary and reasonable costs 
actually incurred in the performance of this contract within the 
categories listed in Paragraph D, below, and subject to the conditions 
and limitations applicable thereto as set out herein and in the attached 
General Provisions (GPs).
    B. The amount budgeted and available as personal compensation to the 
contractor is calculated to cover a calendar period of approximately 
______ (days) (weeks) (months) (years) (which is to include) (1) 
vacation and sick leave which may be earned during contractor's tour of 
duty (GP Clause No. 6), (2) ______ days for authorized travel (GP Clause 
9), and (3) ______ days for orientation and consultation if required by 
the Statement of Duties.
    C. The contractor shall earn vacation leave at the rate of ______ 
days per year under the contract (provided the contract is in force for 
at least 90 days) and shall earn sick leave at the rate of ______ days 
per year under the contract.
    D. Allowable Costs.
    1. Compensation at the rate of LC ______ per (year) (month) (week) 
(day), equivalent to Grade FSN-______/______ in accordance with the 
Mission's Local Compensation Plan. If during the effective period of 
this contract the Local Compensation Plan is revised, contractor's 
compensation will be revised accordingly and contractor will be notified 
in writing by the contracting officer. Adjustments in compensation for 
periods when the contractor is not in compensable pay status shall be 
calculated as follows: Rate of LC ______ per (day) (hour).
    LC ______
    2. Overtime (Unless specifically authorized in the Schedule of this 
contract, no overtime hours shall be allowed hereunder.)
    3. Travel and Transportation (Ref. GP Clause 9). (Includes the value 
of TRs furnished by the Government, not payable to contractor).

a. United States--$______
b. International--$______
c. Cooperating and Third Country--$______, LC ______

    Subtotals Item 3--$______, LC ______

    4. Subsistence or Per Diem (Ref. GP Clause 9).

a. United States--$______

[[Page 124]]

b. International--$______
c. Cooperating and Third Country--$______, LC______
    Subtotals Item 4--$______, LC______

    5. Other Direct Costs

a. Physical Examination (Ref. GP Clause 3)--LC______
b. Miscellaneous--LC______
    Subtotal Item--LC______

    Total Estimated Costs (Lines 1 thru 5) $______ LC ______
    E. Maximum U.S. Dollar and Local Currency Obligation.
    In no event shall the maximum U.S. Dollar obligation under this 
contract exceed $______ nor shall the maximum local currency obligation 
exceed LC ______. Contractor shall keep a close account of all 
obligations incurred and accrued hereunder and promptly notify the 
contracting officer whenever it appears that the said maximum is not 
sufficient to cover all compensation and costs reimbursable which are 
anticipated under the contract.
    F. Under the Joint Incentive Awards Program for FSN monetary awards 
will be made pending availability of funds. The increase for the award 
will be effected by the execution of an SF-1126 which will be attached 
to the contract and will form a part of the contract. In no event may 
costs under the contract exceed the total amount obligated.
    Meritorious Step Increases for FSN PSCs may be authorized provided 
the granting of such increase is the general practice locally.

           Article IV--Costs Reimbursable And Logistic Support

    A. General.
    The contractor shall be provided with or reimbursed in local 
currency

(______) for the following: [Complete]

    B. Method of Payment of Local Currency Costs.
    Those contract costs which are specified as local currency costs in 
Paragraph A, above, if not furnished in kind by the cooperating 
government or the Mission, shall be paid to the contractor in a manner 
adapted to the local situation, based on vouchers submitted in 
accordance with GP Clause 10. The documentation for such costs shall be 
on such forms and in such manner as the Mission Director shall 
prescribe.
    C. Cooperating or U.S. Government Furnished Equipment and 
Facilities.
    [List any logistical support, equipment, and facilities to be 
provided by the cooperating government or the U.S. Government at no cost 
to this contract; e.g., office space, supplies, equipment, secretarial 
support, etc., and the conditions, if any, for use of such equipment.]

                     Article V--Precontract Expenses

    No expense incurred before signing of this contract will be 
reimbursed unless such expense was incurred after receipt and acceptance 
of a precontract expense letter issued to the contractor by the 
Contracting Officer, and then only in accordance with the provisions and 
limitations contained in such letter. The rights and obligations created 
by such letter shall be considered as merged into this contract.

                     Article VI--Additional Clauses

    [Additional Schedule Clauses may be added to meet specific 
requirements of an individual contract.]

11. Optional Schedule for a Contract With a Cooperating Country National 
          or Third Country National Personal Services Contracts

Contract No. ______
Table of Contents
(Optional Schedule)
    [Use of the Optional Schedule is not mandatory. It is intended to 
serve as an alternate procedure for OE funded Cooperating Country 
National and Third Country National PSCs. The schedule was developed for 
use when the Contracting Officer anticipates incremental recurring cost 
funded contracts.
    It should be noted that use of the Optional Schedule eliminates the 
need to amend the contract each time funds are obligated. However, 
Contracting Officer is required to amend each contract not less than 
twice during a 12 month period to ensure that the contract record of 
obligations is up to date and agrees with the figures in the master 
funding document.]
    The Schedule on pages ______ through ______ consists of this Table 
of Contents and the following Articles:

Article I  Statement of Duties
Article II  Period of Service
Article III  Contractor's Compensation and Reimbursement
Article IV  Costs Reimbursable and Logistic Support
Article V  Precontract Expenses
Article VI  Additional Clauses

General Provisions

    The following provisions, numbered as shown below, omitting 
number(s) ______, are the General Provisions (GPs) of this contract.

1. Definitions
2. Compliance with Applicable Laws and Regulations
3. Physical Fitness
4. Security
5. Workweek
6. Leave and Holidays
7. Social Security and Cooperating Country Taxes
8. Insurance

[[Page 125]]

9. Travel and Transportation
10. Payment
11. Contractor-Mission Relationships
12. Termination
13. Allowances
14. Advance of Dollar Funds
15. Conversion of U.S. Dollars to Local Currency
16. Post of Assignment Privileges
17. Release of Information
18. Notices
19. Incentive Awards
20. Training
21. Medical Evacuation Services
Article I--Statement of Duties
    [The statement of duties shall include:
    A. General statement of the purpose of the contract.
    B. Statement of duties to be performed.
    C. Orientation or training to be provided by USAID.]

                      Article II--Period of Service

    Employment under this contract is of a continuing nature. Its 
duration is expected to be part of a series of sequential contracts; all 
contract provisions and clauses and regulatory requirements concerning 
availability of funds and the specific duration of this contract shall 
apply.
    Within 10 days after written notice from the Contracting Offices 
that all clearances have been received, unless another date is specified 
by the Contracting Officer in writing, the contractor shall proceed to 
(name place) and shall promptly commence performance of the duties 
specified in Article I of this contract. The contractor's period of 
service shall be approximately (specify duration from date to date).

        Article III--Contractor's Compensation and Reimbursement

    A. Except as reimbursement may be specifically authorized by the 
Mission Director or Contracting Officer, USAID shall pay the contractor 
compensation after it has accrued and make reimbursements, if any are 
due in currency of the cooperating country (LC) in accordance with the 
prevailing practice of the post or for necessary and reasonable costs 
actually incurred in the performance of this contract within the 
categories listed in paragraph E, below, and subject to the conditions 
and limitations applicable thereto as set out herein and in the attached 
General Provisions (GPs).
    B. The amount budgeted and available as personal compensation to the 
contractor is calculated to cover a calendar period of approximately 
______ (days) (weeks) (months) (years) (which is to include) (1) 
vacation and sick leave which may be earned during the contractor's tour 
of duty (GP Clause No. 6), (2) ______ days for authorized travel (GP 
Clause 9), and (3) ______ days for orientation and consultation if 
required by the Statement of Duties.
    C. The contractor shall earn vacation leave at the rate of ______ 
days per year under the contract (provided the contract is in force for 
at least 90 days) and shall earn sick leave at the rate of ______ days 
per year under the contract.
    D. All employee rights and benefits from the previous contract or 
employment, i.e., accumulated annual and sick leave balances, original 
service computation dates, reserve fund contributions, accumulated 
compensatory time, social security contributions, seniority and 
longevity bonuses are considered allowable costs and as a continuation 
as long as the break in service does not exceed three days.
    E. Allowable Costs.
    1. The following illustrative budget details allowable costs under 
this contract and provides estimated incremental recurrent cost funding 
in the total amount shown. Additional funds for the full term of this 
contract will be provided by the preparation of a master PSC funding 
document issued by the Mission Controller for the purpose of providing 
additional funding for a specific period. The master PSC funding 
document will be attached to this contract and will form a part of the 
executed contract while also serving to amend the budget.
    2. Overtime (Unless specifically authorized in the Schedule of this 
contract, no overtime hours shall be allowed hereunder.)
    LC______
    3. Travel and Transportation (Ref. GP Clause 9). (Includes the value 
of TRs furnished by the Government, not payable to contractor).

a. United States--$______
b. International--$______
c. Cooperating and Third Country--$______, LC ______
    Subtotals Item 3--$______, LC ______

    4. Subsistence or Per Diem (Ref. GP Clause 9.)

a. United States--$______
b. International--$______
c. Cooperating and Third Country--$______, LC ______
    Subtotals Item 4--$______, LC ______

    5. Other Direct Costs.

a. Physical Examination (Ref. GP Clause 3)--$______, LC ______
b. Miscellaneous--$______, LC ______
    Subtotals Item 5--$______, LC ______

Total Estimated Costs (Lines 1 thru 5) $______, LC ______

    F. Allowable costs compensation and all terms and benefits of 
employment under this contract will be in accordance with the Mission's 
local compensation plan. Salary changes and personnel-related contract 
actions will be made by processing the same

[[Page 126]]

forms as used in making such changes and actions for direct-hire FSN 
employees. When issued by the Contracting Officer, the forms utilized 
will be attached to the contract and will form a part of the contract 
terms and conditions.
    Any adjustment or increase in the compensation granted to direct-
hire employees under the local compensation plan will be allowed for in 
PSCs subject to the availability of funds. Such an adjustment will be 
effected by a mass pay adjustment notice from the Contracting Officer, 
which will be attached to the contract and form a part of the executed 
contract.
    At the end of each year of satisfactory service, PSC contractors 
will be eligible to receive an increase equal to one annual step 
increase as shown in the local compensation plan, pending availability 
for funds. Such increase will be effected by the execution of an SF-
1126, Payroll Change Slip which is to be attached to each contract and 
each action forms a part of the official contract file.
    Under the Joint Inventive Awards Program for FSNs, monetary awards 
will be made pending availability of funds. The increase for the award 
will be effected by the execution of an SF-1126 which will be attached 
to the contract and will form a part of the contract. In no event may 
costs under the contract exceed the total amount obligated.
    Meritorious Step Increases for FSN PSCs may be authorized provided 
the granting of such increase is the general practice locally.
    The master PSC funding document may not exceed the term or estimated 
total cost of this contract. Notwithstanding that additional funds are 
obligated under this contract through the issuance and attachment of the 
master PSC funding document, all other contract terms and conditions 
remain in full effect.

           Article IV--Costs Reimbursable and Logistic Support

    A. General.
    The contractor shall be provided with or reimbursed in local 
currency

______ for the following: [Complete]

    B. Method of Payment of Local Currency Costs.
    Those contract costs which are specified as local currency costs in 
Paragraph A, above, if not furnished in kind by the cooperating 
government or the Mission, shall be paid to the contractor in a manner 
adapted to the local situation, based on vouchers submitted in 
accordance with GP Clause 10. The documentation for such costs shall be 
on such forms and in such manner as the Mission Director shall 
prescribe.
    C. Cooperating or U.S. Government Furnished Equipment and 
Facilities.
    [List any logistical support, equipment, and facilities to be 
provided by the cooperating government or the U.S. Government at no cost 
to this contract; e.g., office space, supplies, equipment, secretarial 
support, etc., and the conditions, if any, for use of such equipment.]

                     Article V--Precontract Expenses

    No expense incurred before signing of this contract will be 
reimbursed unless such expense was incurred after receipt and acceptance 
of a precontract expense letter issued to the contractor by the 
Contracting Officer, and then only in accordance with the provisions and 
limitations contained in such letter. The rights and obligations created 
by such letter shall be considered as merged into this contract.

                     Article VI--Additional Clauses

    [Additional Schedule Clauses may be added to meet specific 
requirements of an individual contract.]

    12. General Provisions for a Contract With a Cooperating Country 
     National or With a Third Country National for Personal Services

    To be used to contract with cooperating country nationals or third 
country nationals for personal services.

Index of Clauses
1. Definitions
2. Compliance with Applicable Laws and Regulations
3. Physical Fitness
4. Security
5. Workweek
6. Leave and Holidays
7. Social Security and Cooperating Country Taxes
8. Insurance
9. Travel and Transportation
10. Payment
11. Contractor-Mission Relationships
12. Termination
13. Allowances
14. Advance of Dollar Funds
15. Conversion of U.S. Dollars to Local Currency
16. Post of Assignment Privileges
17. Release of Information
18. Notices
19. Incentive Awards
20. Training
21. Medical Evacuation Services

1. Definitions (July 1993)
    [For use in both Cooperating Country National (CCN) and Third 
Country National (TCN) Contracts].
    (a) USAID shall mean the U.S. Agency for International Development.
    (b) Administrator shall mean the Administrator or the Deputy 
Administrator of the U.S. Agency for International Development.
    (c) Contracting Officer shall mean a person with the authority to 
enter into, administer,

[[Page 127]]

and/or terminate contracts and make related determinations and findings. 
The term includes certain authorized representatives of the Contracting 
Officer acting within the limits of their authority as delegated by the 
Contracting Officer.
    (d) Cooperating Country National shall mean the individual engaged 
to serve in the Cooperating Country under this contract.
    (e) Cooperating Country shall mean the foreign country in or for 
which services are to be rendered hereunder.
    (f) Cooperating Government shall mean the government of the 
Cooperating Country.
    (g) Government shall mean the United States Government.
    (h) Economy Class air travel shall mean a class of air travel which 
is less than business or first class.
    (i) Local Currency shall mean the currency of the cooperating 
country.
    (j) Mission shall mean the United States USAID Mission to, or 
principal USAID office in, the Cooperating Country.
    (k) Mission Director shall mean the principal officer in the Mission 
in the Cooperating Country, or his/her designated representative.
    (l) Third Country National shall mean an individual (i) who is 
neither a citizen of the United States nor of the country to which 
assigned for duty, and (ii) who is eligible for return travel to the 
TCN's home country or country from which recruited at U.S. Government 
expenses, and (iii) who is on a limited assignment for a specific period 
of time.
    (m) Tour of Duty shall mean the contractor's period of service under 
this contract and shall include, authorized leave and international 
travel.
    (n) Traveler shall mean the contractor or dependents of the 
contractor who are in authorized travel status.
    (o) Dependents shall mean spouse and children (including step and 
adopted children who are unmarried and under 21 years of age or, 
regardless of age, are incapable of self-support.

2. Compliance With Laws and Regulations Applicable Abroad (July 1993)

    [For use in both CCN and TCN Contracts].
    (a) Conformity to Laws and Regulations of the Cooperating Country.
    Contractor agrees that, while in the cooperating country, he/she as 
well as authorized dependents will abide by all applicable laws and 
regulations of the cooperating country and political subdivisions 
thereof.
    (b) Purchase or Sale of Personal Property or Automobiles. [For TCNs 
Only].
    To the extent permitted by the cooperating country, the purchase, 
sale, import, or export of personal property or automobiles in the 
cooperating country by the contractor shall be subject to the same 
limitations and prohibitions which apply to Mission U.S.-citizen direct-
hire employees.
    (c) Code of Conduct.
    The contractor shall, during his/her tour of duty under this 
contract, be considered an ``employee'' (or if his/her tour of duty is 
for less than 130 days, a ``special Government employee'') for the 
purposes of, and shall be subject to, the provisions of 18 U.S.C. 202(a) 
the AID General Notice entitled Employee Review of the New Standards of 
Conduct. The contractor acknowledges receipt of a copy of these 
documents by his/her acceptance of this contract.

    3. Physical Fitness (July 1993)

    [For use in both CCN and TCN Contracts].
    (a) Cooperating Country National.
    The contractor shall be examined by a licensed doctor of medicine, 
and shall obtain a statement of medical opinion that, in the doctor's 
opinion, the contractor is physically qualified to engage in the type of 
activity for which he/she is to be employed under the contract. A copy 
of the medical opinion shall be provided to the Contracting Officer 
before the contractor starts work under the contract. The contractor 
shall be reimbursed for the cost of the physical examination based on 
the rates prevailing locally for such examinations in accordance with 
Mission practice.
    (b) Third Country National.
    (i) The contractor shall obtain a physical examination for himself/
herself and any authorized dependents by a licensed doctor of medicine. 
The contractor shall obtain a statement of medical opinion from the 
doctor that, in the doctor's opinion, the contractor is physically 
qualified to engage in the type of activity for which he/she is to be 
employed under the contract, and the contractor's authorized dependents 
are physically qualified to reside in the cooperating country. A copy of 
that medical opinion shall be provided to the Contracting Officer prior 
to the dependents' departure for the cooperating country.
    (ii) The contractor shall be reimbursed for the cost of the physical 
examinations mentioned above as follows: (1) based on those rates 
prevailing locally for such examinations in accordance with Mission 
practice or (2) if not done locally, not to exceed $100 per examination 
for the contractor's dependents of 12 years of age and over and not to 
exceed $40 per examination for contractor's dependents under 12 years of 
age. The contractor shall also be reimbursed for the cost of all 
immunizations normally authorized and extended to FSN employees.

4. Security (July 1993)

    [For use in both CCN and TCN Contracts].
    (a) The contractor is obligated to notify immediately the 
Contracting Officer if the contractor is arrested or charged with any 
offense during the term of this contract.

[[Page 128]]

    (b) The contractor shall not normally have access to classified or 
administratively controlled information and shall take conscious steps 
to avoid receiving or learning of such information. However, based on 
contractor's need to know, Mission may authorize access to 
administratively controlled information for performance of assigned 
scope of work on a case-by-case basis in accordance with USAID Handbook 
6 or superseding ADS Chapters.
    (c) The contractor agrees to submit immediately to the Mission 
Director or Contracting Officer a complete detailed report, marked 
``Privileged Information'', of any information which the contractor may 
have concerning existing or threatened espionage, sabotage, or 
subversive activity against the United States of America or the USAID 
Mission or the cooperating country government.

5. Workweek (Oct 1987)

    [For use in both CCN and TCN Contracts].
    The contractor's workweek shall not be less than 40 hours, unless 
otherwise provided in the Schedule, and shall coincide with the workweek 
for those employees of the Mission or the cooperating country agency 
must closely associated with the work of this contract. If approved in 
advance in writing, overtime worked by the contractor shall be paid in 
accordance with the procedures governing premium compensation applicable 
to direct-hire foreign service national employees. If the contract is 
for less than full time (40 hours weekly), the leave earned shall be 
prorated.

6. Leave and Holidays (Oct 1987)

    [For use in both CCN and TCN Contracts].
    (a) Vacation Leave.
    The contractor may accrue, accumulate, use and be paid for vacation 
leave in the same manner as such leave is accrued, accumulated, used and 
paid to foreign service national direct-hire employees of the Mission. 
No vacation leave shall be earned if the contract is for less than 90 
days. Unused vacation leave may be carried over under an extension or 
renewal of the contract as long as it conforms to Mission policy and 
practice. With the approval of the Mission Director, and if the 
circumstances warrant, a contractor may be granted advance vacation 
leave in excess of that earned, but in no case shall a contractor be 
granted advance vacation leave in excess of that which he/she will earn 
over the life of the contract. The contractor agrees to reimburse USAID 
for leave used in excess of the amount earned during the contractor's 
assignment under the contract.
    (b) Sick Leave.
    The contractor may accrue, accumulate, and use sick leave in the 
same manner as such leave is accrued, accumulated and used by foreign 
service national direct-hire employees of the Mission. Unused sick leave 
may be carried over under an extension of the contract. The contractor 
will not be paid for sick leave earned but unused at the completion of 
this contract.
    (c) Leave Without Pay.
    Leave without pay may be granted only with the written approval of 
the Contracting Officer or Mission Director.
    (d) Holidays.
    The contractor shall be entitled to all holidays granted by the 
Mission to direct-hire cooperating country national employees who are on 
comparable assignments.

7. Social Security and Cooperating Country Taxes (Dec 1986)

    [For use in both CCN and TCN Contracts].
    Funds for Social Security, retirement, pension, vacation or other 
cooperating country programs as required by local law shall be deducted 
and withheld in accordance with laws and regulations and rulings of the 
cooperating country or any agreement concerning such withholding entered 
into between the cooperating government and the United States 
Government.

8. Insurance (July 1993)

    [For use in both CCN and TCN Contracts].
    (a) Worker's Compensation Benefits.
    The contractor shall be provided worker's compensation benefits 
under the Federal Employees Compensation Act.
    (b) Health and Life Insurance.
    The contractor shall be provided personal health and life insurance 
benefits on the same basis as they are granted to direct-hire CCNs and 
TCN employees at the post under the Post Compensation Plan.
    (c) Insurance on Private Automobiles--Contractor Responsibility [For 
use in TCN contracts]. If the contractor or dependents transport, or 
cause to be transported, any privately owned automobile(s) to the 
cooperating country, or any of them purchase an automobile within the 
cooperating country, the contractor agrees to ensure that all such 
automobile(s) during such ownership within the cooperating country will 
be covered by a paid-up insurance policy issued by a reliable company 
providing the following minimum coverages, or such other minimum 
coverages as may be set by the Mission Director, payable in U.S. dollars 
or its equivalent in the currency of the cooperating country: injury to 
persons, $10,000/$20,000; property damage, $5,000. The contractor 
further agrees to deliver, or cause to be delivered to the Mission 
Director, copies of the insurance policies required by this clause or 
satisfactory proof of the existence thereof, before such automobile(s) 
is operated within the cooperating country. The premium costs for such 
insurance shall not be a reimbursable cost under this contract.
    (d) Claims for Private Personal Property Losses [For use in TCN 
contracts]. The contractor shall be reimbursed for private personal 
property losses in accordance with

[[Page 129]]

USAID Handbook 23, ``Overseas Support'', Chapter 10, or superseding ADS 
Chapter.

9. Travel and Transportation Expenses (July 1993)

    [For use in both CCN and TCN Contracts as appropriate].
    (a) General. The contractor will be reimbursed in currency 
consistent with the prevailing practice at post and at the rates 
established by the Mission Director for authorized travel in the 
cooperating country in connection with duties directly referable to work 
under this contract. In the absence of such established rates, the 
contractor shall be reimbursed for actual costs of authorized travel in 
the cooperating country if not provided by the cooperating government or 
the Mission in connection with duties directly referable to work 
hereunder, including travel allowances at rates prescribed by USAID 
Handbook 22, ``Foreign Service Travel Regulations'' or superseding ADS 
Chapters as from time to time amended. The Executive or Administrative 
Officer at the Mission may furnish Transportation Requests (TR's) for 
transportation authorized by this contract which is payable in local 
currency or is to originate outside the United States. When 
transportation is not provided by Government issued TR, the contractor 
shall procure the transportation, and the costs will be reimbursed. The 
following paragraphs provide specific guidance and limitations on 
particular items of cost.
    (b) International Travel. For travel to and from post of assignment 
the TCN contractor shall be reimbursed for travel costs and travel 
allowances from place of residence in the country of recruitment (or 
other location provided that the cost of such travel does not exceed the 
cost of the travel from the place of residence) to the post of duty in 
the cooperating country and return to place of residence in the country 
of recruitment (or other location provided that the cost of such travel 
does not exceed the cost of travel from the post of duty in the 
cooperating country to the contractor's residence) upon completion of 
services by the individual. Reimbursement for travel will be in 
accordance with USAID's established policies and procedures for its CCN 
and TCN direct-hire employees and the provisions of this contract, and 
will be limited to the cost of travel by the most direct and expeditious 
route. If the contract is for longer than one year and the contractor 
does not complete one full year at post of duty (except for reasons 
beyond his/her control), the cost of going to and from the post of duty 
for the contractor and his/her dependents are not reimbursable 
hereunder. If the contractor serves more than one year but less than the 
required service in the cooperating country (except for reasons beyond 
his/her control) costs of going to the post of duty are reimbursable 
hereunder but the cost of going from post of duty to the contractor's 
permanent, legal place of residence at the time he or she was employed 
for work under this contract are not reimbursable under this contract 
for the contractor and his/her dependents. When travel is by economy 
class accommodations, the contractor will be reimbursed for the cost of 
transporting up to 10 kilograms/22 pounds of accompanied personal 
baggage per traveler in addition to that regularly allowed with the 
economy ticket provided that the total number of pounds of baggage does 
not exceed that regularly allowed for first class travelers. Travel 
allowances for travelers shall not be in excess of the rates authorized 
in the Standardized Regulations (Government Civilians, Foreign Areas) 
hereinafter referred to as the Standardized Regulations--as from time to 
time amended, for not more than the travel time required by scheduled 
commercial air carrier using the most expeditious route. One stopover 
enroute for a period of not to exceed 24 hours is allowable when the 
traveler uses economy class accommodations for a trip of 14 hours or 
more of scheduled duration. Such stopover shall not be authorized when 
travel is by indirect route or is delayed for the convenience of the 
traveler. Per diem during such stopover shall be paid in accordance with 
the Federal Travel Regulations as from time to time amended.
    (c) Local Travel.--Reimbursement for local travel in connection with 
duties directly referable to the contract shall not be in excess of the 
rates established by the Mission Director for the travel costs of 
travelers in the Cooperating Country. In the absence of such established 
rates the contractor shall be reimbursed for actual travel costs in the 
Cooperating Country by the Mission, including travel allowances at rates 
not in excess of those prescribed by the Standardized Regulations.
    (d) Indirect Travel for Personal Convenience of a TCN. When travel 
is performed by an indirect route for the personal convenience of the 
traveler, the allowable costs of such travel will be computed on the 
basis of the cost of allowable air fare via the direct usually traveled 
route. If such costs include fares for air or ocean travel by foreign 
flag carriers, approval for indirect travel by such foreign flag 
carriers must be obtained from the Contracting Officer or the Mission 
Director before such travel is undertaken, otherwise only that portion 
of travel accomplished by the United States-flag carriers will be 
reimbursable within the above limitation of allowable costs.
    (e) Limitation on Travel by TCN Dependents. Travel costs and 
allowances will be allowed for authorized dependents of the contractor 
and such costs shall be reimbursed for travel

[[Page 130]]

from place of abode in the country of recruitment to the assigned 
station in the Cooperating Country and return, only if the dependent 
remains in the Cooperating Country for at least 9 months or one-half of 
the required tour of duty of the contract, whichever is greater, except 
as otherwise authorized hereunder for education, medical, or emergency 
visitation travel. Dependents of the TCN contractor must return to the 
country of recruitment or home country within thirty days of the 
termination or completion of the contractor's employment, otherwise such 
travel will not be reimbursed under this contract.
    (f) Delays Enroute. The contractor may be granted reasonable delays 
enroute while in travel status when such delays are caused by events 
beyond the control of the contractor and are not due to circuitous 
routing. It is understood that if delay is caused by physical 
incapacitation, he/she shall be eligible for such sick leave as provided 
under the ``Leave and Holidays'' clause of this contract.
    (g) Travel by Privately Owned Automobile (POV). If travel by POV is 
authorized in the contract schedule or approved by the Contracting 
Officer, the contractor shall be reimbursed for the cost of travel 
performed in his/her POV at a rate not to exceed that authorized in the 
Federal Travel Regulations plus authorized per diem for the employee 
and, if the POV is being driven to or from the cooperating country as 
authorized under the contract, for each of the authorized dependents 
traveling in the POV, provided that the total cost of the mileage and 
per diem paid to all authorized travelers shall not exceed the total 
constructive cost of fare and normal per diem by all authorized 
travelers by surface common carrier or authorized air fare, whichever is 
less.
    (h) Emergency and Irregular Travel and Transportation. [For TCNs 
only]. Emergency transportation costs and travel allowances while 
enroute, as provided in this section, will be reimbursed not to exceed 
amounts authorized by the Foreign Service Travel Regulations for FSN 
direct-hire employees in like circumstances under the following 
conditions:
    (1) The costs of going from post of duty in the cooperating country 
to another approved location for the contractor and authorized 
dependents and returning to post of duty, subject to the prior written 
approval of the Mission Director, when such travel is necessary for one 
of the following reasons:
    (i) Need for medical care beyond that available within the area to 
which contractor is assigned.
    (ii) Serious effect on physical or mental health if residence is 
continued at assigned post of duty.
    (iii) Serious illness, injury, or death of a member of the 
contractor's immediate family or a dependent, including preparation and 
return of the remains of a deceased contractor or his/her dependents.
    (2) Emergency evacuation when ordered by the principal U.S. 
Diplomatic Officer in the cooperating country. Transportation and travel 
allowances at safe haven and the transportation of household effects and 
automobile or storage thereof when authorized by the Mission Director, 
shall be payable in accordance with established Government regulations.
    (3) The Mission Director may also authorize emergency or irregular 
travel and transportation in other situations when in his/her opinion 
the circumstances warrant such action. The authorization shall include 
the kind of leave to be used and appropriate restrictions as to time 
away from post, transportation of personal and household effects, etc.
    (i) Country of Recruitment Travel and Transportation. [For TCNs 
only]. The contractor shall be reimbursed for actual transportation 
costs and travel allowances in the country of recruitment as authorized 
in the Schedule or approved in advance by the Contracting Officer or the 
Mission Director. Transportation costs and travel allowances shall not 
be reimbursed in any amount greater than the cost of, and time required 
for, economy-class commercial-scheduled air travel by the most 
expeditious route except as otherwise provided in paragraph (h) above, 
unless economy air travel is not available and the contractor adequately 
documents this to the satisfaction of the Contracting Officer in 
documents submitted with the voucher.
    (j) Rest and Recuperation Travel. [For TCNs only].
    If approved in writing by the Mission Director, the contractor and 
his/her dependents shall be allowed rest and recuperation travel on the 
same basis as direct-hire TCN employees and their dependents at the post 
under the local compensation plan.
    (k) Transportation of Personal Effects (Excluding Automobiles and 
Household Goods). [For TCNs only].
    (1) General. Transportation costs will be paid on the same basis as 
for direct-hire employees at post serving the same length tour of duty, 
as authorized in the schedule. Transportation, including packing and 
crating costs, will be paid for shipping from contractor's residence in 
the country of recruitment or other location, as approved by the 
Contracting Officer (provided that the cost of transportation does not 
exceed the cost from the contractor's residence) to post of duty in the 
cooperating country and return to the country of recruitment or other 
location provided the cost of transportation of the personal effects of 
the contractor not to exceed the limitations in effect for such 
shipments for USAID direct-hire employees in accordance with the Foreign 
Service Travel

[[Page 131]]

Regulations in effect at the time shipment is made. These limitations 
may be obtained from the Contracting Officer. The cost of transporting 
household goods shall not exceed the cost of packing, crating, and 
transportation by surface common carrier.
    (2) Unaccompanied Baggage. Unaccompanied baggage is considered to be 
those personal belongings needed by the traveler immediately upon 
arrival of the contractor and dependents. To permit the arrival of 
effects to coincide with the arrival of the contractor and dependents, 
consideration should be given to advance shipments of unaccompanied 
baggage. The contractor will be reimbursed for costs of shipment of 
unaccompanied baggage (in addition to the weight allowance for household 
effects) not to exceed the limitations in effect for USAID direct-hire 
employees in accordance with the Foreign Service Travel Regulations in 
effect when shipment is made. These limitations are available from the 
Contracting Officer. This unaccompanied baggage may be shipped as air 
freight by the most direct route between authorized points of origin and 
destination regardless of the modes of travel used.
    (l) Reduced Rates on U.S.-Flag Carriers. Reduced rates on U.S.-flag 
carriers are in effect for shipments of household goods and personal 
effects of USAID contractors between certain locations. These reduced 
rates are available provided the shipper furnishes to the carrier at the 
time of the issuance of the Bill of Lading documentary evidence that the 
shipment is for the account of USAID. The Contracting Officer will, on 
request, furnish to the contractor current information concerning the 
availability of a reduced rate with respect to any proposed shipment. 
The contractor will not be reimbursed for shipments of household goods 
or personal effects in amounts in excess of the reduced rates which are 
available in accordance with the foregoing.
    (m) Transportation of things. [For TCNs Only]. Where U.S. flag 
vessels are not available, or their use would result in a significant 
delay, the contractor may obtain a release from the requirement to use 
U.S. flag vessels from the Transportation Division, Office of 
Procurement, U.S. Agency for International Development, Washington, DC 
20523-1419, or the Mission Director, as appropriate, giving the basis 
for the request.
    (n) Repatriation Travel. [For TCNs Only]. Notwithstanding other 
provisions of this Clause 9, a TCN must return to the country of 
recruitment or to the TCN's home country within 30 days after 
termination or completion of employment or forfeit all right to 
reimbursement for repatriation travel. The return travel obligation 
[repatriation travel] assumed by the U.S. Government may have been the 
obligation of another employer in the area of assignment if the employee 
has been in substantially continuous employment which provided for the 
TCN's return to home country or country from which recruited.
    (o) Storage of household effects. [For TCNs Only]. The cost of 
storage charges (including packing, crating, and drayage costs) in the 
country of recruitment of household goods of regular employees will be 
permitted in lieu of transportation of all or any part of such goods to 
the Cooperating Country under paragraph (k) above provided that the 
total amount of effects shipped to the Cooperating Country or stored in 
the country of recruitment shall not exceed the amount authorized for 
USAID direct-hire employees under the Foreign Service Travel 
Regulations. These amounts are available from the Contracting Officer.

10. Payment (May 1997)

    [For use in both CCN and TCN Contracts].
    (a) Payment of compensation shall be based on written documentation 
supporting time and attendance which may be (1) maintained by the 
Mission in the same way as for direct-hire CCNs and TCNs or (2) the 
contractor may submit such written documentation in a form acceptable to 
Mission policy and practice as required for other personal services 
contractors and as directed by the Mission Controller or paying office. 
The documentation will also provide information required to be filed 
under cooperating country laws to permit withholding by USAID of funds, 
if required, as described in the clause of these General Provisions 
entitled Social Security and Cooperating Country Taxes.
    (b) Any other payments due under this contract shall be as 
prescribed by Mission policy for the type of payment being made.

11. Contractor-Mission Relationships (Dec. 1986)

    [For use in both CCN and TCN Contracts].
    (a) The contractor acknowledges that this contract is an important 
part of the U.S. Foreign Assistance Program and agrees that his/her 
duties will be carried out in such a manner as to be fully commensurate 
with the responsibilities which this entails. Favorable relations 
between the Mission and the Cooperating Government as well as with the 
people of the cooperating country require that the contractor shall show 
respect for the conventions, customs, and institutions of the 
cooperating country and not become involved in any illegal political 
activities.
    (b) If the contractor's conduct is not in accordance with paragraph 
(a), the contract may be terminated pursuant to the General Provision of 
this contract, entitled ``Termination.'' If a TCN, the contractor 
recognizes the right of the U.S. Ambassador to direct his/her immediate 
removal from any country when, in the discretion of the Ambassador, the 
interests of the United States so require.

[[Page 132]]

    (c) The Mission Director is the chief representative of USAID in the 
cooperating country. In this capacity, he/she is responsible for the 
total USAID Program in the cooperating country including certain 
administrative responsibilities set forth in this contract and for 
advising USAID regarding the performance of the work under the contract 
and its effect on the U.S. Foreign Assistance Program. The contractor 
will be responsible for performing his/her duties in accordance with the 
statement of duties called for by the contract. However, he/she shall be 
under the general policy guidance of the Mission Director and shall keep 
the Mission Director or his/her designated representative currently 
informed of the progress of the work under this contract.

12. Termination (Nov. 1989)

    [For use in both CCN and TCN Contracts].
    (This is an approved deviation to be used in place of the clause 
specified in FAR 52.249-12.)
    (a) The Government may terminate performance of work under this 
contract in whole or, from time to time, in part:
    (1) For cause, which may be effected immediately after establishing 
the facts warranting the termination, by giving written notice and a 
statement of reasons to the contractor in the event (i) the contractor 
commits a breach or violation of any obligations herein contained, (ii) 
a fraud was committed in obtaining this contract, or (iii) the 
contractor is guilty (as determined by USAID) of misconduct in the 
cooperating country. Upon such a termination, the contractor's right to 
compensation shall cease when the period specified in such notice 
expires or the last day on which the contractor performs services 
hereunder, whichever is earlier. No costs of any kind incurred by the 
contractor after the date such notice is delivered shall be reimbursed 
hereunder except the cost of return transportation (not including travel 
allowances), if approved by the Contracting Officer. If any costs 
relating to the period subsequent to such date have been paid by USAID, 
the contractor shall promptly refund to USAID any such prepayment as 
directed by the Contracting Officer.
    (2) For the convenience of USAID, by giving not less than 15 
calender days advance written notice to the contractor. Upon such a 
termination, contractor's right to compensation shall cease when the 
period specified in such notice expires except that the contractor shall 
be entitled to any accrued, unused vacation leave, return transportation 
costs and travel allowances and transportation of unaccompanied baggage 
costs at the rates specified in the contract and subject to the 
limitations which apply to authorized travel status.
    (3) For the convenience of USAID, when the contractor is unable to 
complete performance of his/her services under the contract by reason of 
sickness or physical or emotional incapacity based upon a certification 
of such circumstances by a duly qualified doctor of medicine approved by 
the Mission. The contract shall be deemed terminated upon delivery to 
the contractor of a termination notice. Upon such a termination, the 
contractor shall not be entitled to compensation except to the extent of 
any accrued, unused vacation leave, but shall be entitled to return 
transportation, travel allowances, and unaccompanied baggage costs at 
rates specified in the contract and subject to the limitations which 
apply to authorized travel status.
    (b) The contractor, with the written consent of the Contracting 
Officer, may terminate this contract upon at least 15 days' written 
notice to the Contracting Officer.

13. Allowances (Dec. 1986)

    [For TCNs only].
    Allowances will be granted to the contractor and authorized 
dependents on the same basis as to direct-hire TCN employees at the post 
under the Post Compensation Plan. The allowances provided shall be paid 
to the contractor in the currency of the cooperating country or in 
accordance with the practice prevailing at the Mission.

14. Advance of Dollar Funds (Dec 1986)

    [For TCNs only].
    If requested by the contractor and authorized in writing by the 
Contracting Officer, USAID will arrange for an advance of funds to 
defray the initial cost of travel, travel allowances, authorized 
precontract expenses, and shipment of personal property. The advance 
shall be granted on the same basis as to an USAID U.S.-citizen direct-
hire employee in accordance with USAID Handbook 22, Chapter 4 or 
superseding ADS Chapters.

15. Conversion of U.S. Dollars To Local Currency (Dec 1986)

    [For TCNs only].
    Upon arrival in the cooperating country, and from time to time as 
appropriate, the contractor shall consult with the Mission Director or 
his/her authorized representative who shall provide, in writing, the 
policy the contractor shall follow in the conversion of one currency to 
another currency. This may include, but not be limited to, the 
conversion of said currency through the cognizant U.S. Disbursing 
Officer, or Mission Controller, as appropriate.

16. Post of Assignment Privileges (Dec 1986)

    [For TCNs only].
    Privileges such as the use of APO, PX's, commissaries and officer's 
clubs are established at posts abroad pursuant to agreements between the 
U.S. and host governments. These facilities are intended for and usually 
limited to U.S. citizen members of

[[Page 133]]

the official U.S. Mission including the Embassy, USAID, Peace Corps, 
U.S. Information Services and the Military. Normally, the agreements do 
not permit these facilities to be made available to non-U.S. citizens if 
they are under contract to the United States Government. However, in 
those cases where the facilities are open to TCN contractor personnel, 
they may be used.

17. Release Of Information (Dec 1986)

    [For use in both CNN and TCN Contracts].
    All rights in data and reports shall become the property of the U.S. 
Government. All information gathered under this contract by the 
contractor and all reports and recommendations hereunder shall be 
treated as privileged information by the contractor and shall not, 
without the prior written approval of the Contracting Officer, be made 
available to any person, party, or government, other than USAID, except 
as otherwise expressly provided in this contract.

18. Notices (Dec 1986)

    [For use in both CNN and TCN Contracts].
    Any notice, given by any of the parties hereunder, shall be 
sufficient only if in writing and delivered in person or sent by 
telegraph, telegram, registered, or regular mail as follows:
    (a) TO USAID: To the Mission Director of the Mission in the 
Cooperating Country with a copy to the appropriate Contracting Officer.
    (b) TO THE CONTRACTOR: At his/her post of duty while in the 
Cooperating Country and at the contractor's address shown on the Cover 
Page of this contract or to such other address as either of such parties 
shall designate by notice given as herein required.
    Notices hereunder shall be effective when delivered in accordance 
with this clause or on the effective date of the notice, whichever is 
later.

19. Incentive Awards (Dec 1996)

    [For CNN and TCN Contracts].
    (a) All Cooperating Country National (CCN) Personal Services 
Contractors (PSCs) and Third Country Nationals (TCNs) of the Foreign 
Affairs Community are eligible for the Joint Embassy Incentive Awards 
Program. The program is administered by each post's (Embassy) Joint 
Country Awards Committee.
    (b) Meritorious Step Increases
    Meritorious step increases may be granted to CNNs and TCNs paid 
under the local compensation plan provided the granting of such 
increases is the general practice locally.

20. Training (July 1993)

    [For CNN and TCN Contracts].
    The contractor may be provided job related training to develop 
growth potential, expand capabilities and increase knowledge and skills. 
The training may be funded under the personal services contract.

21. Medical Evacuation (MEDEVAC) Services (July 1993)

    [For TCN Contracts Only].
    (a) The contractor agrees to obtain medevac service coverage for 
himself/herself and his/her authorized dependents while performing 
personal services abroad. Coverage shall be obtained pursuant to the 
terms of the contract between USAID and USAID's medevac service provider 
unless exempted in accordance with paragraph (b).
    (b) The following are exempted from the requirements in paragraph 
(a):
    (i) Contractors and their dependents with a health insurance program 
that includes sufficient medevac coverage as approved by the Contractor 
Officer.
    (ii) Contractors and their dependents located at Missions where the 
Mission Director makes a written determination to waive the requirement 
for such coverage based on findings that the quality of local medical 
services or other circumstances obviate the need for such coverage.
    (c) Information on the current medevac service provider, including 
application procedures, is available from the Contracting Officer.

                             13. FAR Clauses

    The following FAR Clauses are always to be used along with the 
General Provisions. They are required in full text.

1. Covenant Against Contingent Fees 52.203-5
2. Disputes 52.233-1 (Alternate 1)
3. Preference for U.S. Flag Air Carriers 52.247-63

    The following FAR Clauses are to be used along with the General 
Provisions, and when appropriate, be incorporated in each personal 
services contract by reference:

1. Anti-Kickback Procedures  52.203-7
2. Limitation on Payments to Influence Certain Federal Transactions  
52.203-12
3. Audit and Records--Negotiation  52.215-2
4. Privacy Act Notification  552.224-1
5. Privacy Act  52.224-2
6. Taxes--Foreign Cost Reimbursement Contracts  52.229-8
7. Interest  52.232-17
8. Limitation of Cost  52.232-20
9. Limitation of Funds  52.232-22
10. Assignment of Claims  52.232-23
11. Protection of Government Buildings, Equipment, and Vegetation  
52.237-2
12. Notice of Intent to Disallow Costs  52.242-1
13. Inspection  52.246-5
14. Limitation of Liability--Services  52.246-25
[62 FR 42929, Aug. 11, 1997]

[[Page 135]]



                CHAPTER 8--DEPARTMENT OF VETERANS AFFAIRS




  --------------------------------------------------------------------

  Editorial Note:  Nomenclature changes affecting chapter 8 appear at 54 
FR 40062, Sept. 29, 1989.

                          SUBCHAPTER A--GENERAL
Part                                                                Page
801             Veterans Affairs Acquisition Regulations 
                    System..................................         137
802             Definitions of words and terms..............         153
803             Improper business practices and personal 
                    conflicts of interest...................         153
804             Administrative matters......................         155
                   SUBCHAPTER B--ACQUISITION PLANNING
805             Publicizing contract actions................         156
806             Competition requirements....................         156
807             Acquisition planning........................         159
808             Required sources of supplies and services...         159
809             Contractor qualifications...................         161
810             Specifications, standards and purchase order 
                    descriptions............................         165
812             Contract delivery or performance............         170
          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
813             Small purchase and other simplified purchase 
                    procedures..............................         172
814             Sealed bidding..............................         172
815             Contracting by negotiation..................         178
816             Types of contracts..........................         181
817             Special contracting methods.................         182
                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
819             Small business and small disadvantaged 
                    business concerns.......................         184
822             Application of labor laws to Government 
                    acquisitions............................         190
824             Protection of privacy and freedom of 
                    information.............................         191

[[Page 136]]

825             Foreign acquisition.........................         191
             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
828             Bonds and insurance.........................         195
829             Taxes.......................................         196
831             Contract cost principles and procedures.....         198
832             Contract financing..........................         202
833             Protests, disputes, appeals.................         203
             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING
836             Construction and architect-engineer 
                    contracts...............................         208
837             Service contracting.........................         212
                    SUBCHAPTER G--CONTRACT MANAGEMENT
842             Contract administration.....................         217
846             Quality assurance...........................         219
847             Transportation..............................         221
849             Termination of contracts....................         222
                     SUBCHAPTER H--CLAUSES AND FORMS
852             Solicitation provisions and contract clauses         225
853             Forms.......................................         251
           SUBCHAPTER I--DEPARTMENT SUPPLEMENTARY REGULATIONS
870             Special procurement controls................         254
871             Loan guaranty and vocational rehabilitation 
                    and counseling programs.................         256

[[Page 137]]



                          SUBCHAPTER A--GENERAL





PART 801--VETERANS AFFAIRS ACQUISITION REGULATIONS SYSTEM--Table of Contents




Sec.
801.000  Scope of part.

               Subpart 801.1--Purpose, Authority, Issuance

801.101  Purpose.
801.102  Authority.
801.103  Applicability.
801.103-70  Exclusions.

                      Subpart 801.2--Administration

801.201-1  The two councils.

            Subpart 801.3--Department Acquisition Regulations

801.301  Policy.
801.301-70  Paperwork Reduction Act requirements.
801.303  Codification and public participation.
801.304  Department control and compliance procedures.

             Subpart 801.4--Deviations From the FAR or VAAR

801.403  Individual deviations.
801.404  Class deviations.

        Subpart 801.6--Contracting Authority and Responsibilities

801.601  General.
801.602  Contracting officers.
801.602-2  Responsibilities.
801.602-3  Ratification of unauthorized commitments.
801.602-70  Legal/technical review requirements to be met prior to 
          contract execution.
801.602-71  Processing contracts for legal/technical review.
801.602-72  Documents to be submitted for legal review.
801.602-73  Certification by reviewing official.
801.602-74  Results of General Counsel's legal review.
801.603  Selection, appointment, and termination of appointment.
801.603-1  General.
801.603-70  Representatives of contracting officers.
801.603-71  Representatives of contracting officers; receipt of 
          equipment, supplies and nonpersonal services.
801.670  Special and limited delegation.
801.670-1  Issue of Government bills of lading--transportation of 
          remains of deceased beneficiaries.
801.670-2  Issue of Government bills of lading--transportation of 
          property.
801.670-3  Medical, dental, and ancillary service.
801.670-4  National Cemetery System.
801.670-5  Letters of agreement.
801.680  Contracting authority of the Inspector General.
801.690  VA Contracting Officer Certification Program.
801.690-1  Definitions.
801.690-2  General.
801.690-3  Responsibility for administration of Contracting Officer 
          Certification Program (COCP).
801.690-4  Selection.
801.690-5  Appointment.
801.690-6  Termination.
801.690-7  Interim appointment provisions.
801.690-8  Distribution of SF 1402, Certificate of Appointment.
801.690-9  Post appointment maintenance of certifications. [Reserved]

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12583, Mar. 29, 1984, unless otherwise noted.



801.000  Scope of part.

    This part prescribes general policies and background regarding the 
Veterans Affairs Acquisition Regulations (VAAR). It includes information 
regarding the maintenance and administration of the VAAR and includes 
procedures for deviations from the VAAR and the Federal Acquisition 
Regulations (FAR).
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 31961, Aug. 3, 1989]



               Subpart 801.1--Purpose, Authority, Issuance



801.101  Purpose.

    (a) This subpart establishes Chapter 8, Veterans Affairs Acquisition 
Regulations, of Title 48--Federal Acquisition Regulation System, Code of 
Federal Regulations.
    (b) The VAAR must be utilized in conjunction with the FAR. The VAAR 
cannot be utilized by itself.

[[Page 138]]



801.102  Authority.

    The VAAR and any amendments thereto are issued by the Secretary of 
Veterans Affairs as provided by 38 U.S.C. 210 and the Federal Property 
and Administrative Services Act of 1949 (40 U.S.C. 486(c)).
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 31961, Aug. 3, 1989]



801.103  Applicability.

    (a) The FAR and the VAAR apply to all acquisitions of the Department 
(including construction) made with appropriated funds and procurements 
made with Supply Fund monies (38 U.S.C. 5021).
    (b) The FAR and VAAR will apply to the special procurement programs 
authorized by Title 38 U.S. Code (Viz., Veterans Canteen Service and the 
Loan Guaranty programs), to the extent indicated in the VAAR.
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 40062, Sept. 29, 1989]



801.103-70  Exclusions.

    The FAR and VAAR will not apply to purchases and contracts which 
utilize General Post Funds when such regulations would infringe upon a 
donor's prerogative to specify the exact item to be purchased and/or the 
source of supply.



                      Subpart 801.2--Administration



801.201-1  The two councils.

    A designee of the Office of Acquisition and Materiel Management will 
represent the Department of Veterans Affairs on the CAA (Civilian Agency 
Acquisition) Council.
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 31962, Aug. 3, 1989]



            Subpart 801.3--Department Acquisition Regulations



801.301  Policy.

    (a) VAAR, amendments and interim changes thereto will be issued by 
the Secretary of Veterans Affairs after necessary reviews by cognizant 
VA officials.
    (b) Implementing procedures, instructions and guidelines necessary 
to implement the VAAR and the FAR may be issued by the heads of 
contracting activities. Such issuances may include delegations of 
authority, review and approval for acquisition action up to the dollar 
level delegated to that contracting activity by this regulation as well 
as providing procedural guidance for users. Such issuances will be the 
minimum necessary to provide a logical implementation of FAR and VAAR 
requirements and will be internal to the facility, i.e., it will not 
specify reporting/recordkeeping requirements for the public (see 
801.301-70(b)).
[49 FR 12583, Mar. 29, 1984, as amended at 52 FR 28559, July 31, 1987; 
54 FR 31962, Aug. 3, 1989; 61 FR 20491, May 7, 1996]



801.301-70  Paperwork Reduction Act requirements.

    (a) It is the policy of the Government to keep to the minimum the 
amount of recordkeeping and reporting required of the public. This 
objective applies to the Department of Veterans Affairs acquisition 
system.
    (b)(1) Contractors will not be requested to maintain systems of 
records unless prescribed in FAR or this VAAR. A deviation to this 
prohibition may be processed in accordance with 801.403 in order to 
allow the contracting officer to require contractor reporting or 
recordkeeping beyond that prescribed in FAR and VAAR. The request for 
deviation will clearly specify what information or recordkeeping will be 
required and why it is required. The request will be signed by the head 
of the contracting activity.
    (2) The Deputy Assistant Secretary for Acquisition and Materiel 
Management (93) will review the request and upon concurrence will 
likewise submit the request to Office of Management and Budget (OMB) for 
approval as prescribed by the Paperwork Reduction Act of 1980. If 
approved, the Deputy Assistant Secretary for Acquisition and Materiel 
Management will send the approval back to the requester with the OMB 
clearance number.
    (c) In accordance with the Paperwork Reduction Act of 1980 (Pub. L. 
96-511), the reporting or recordkeeping provisions that are included in 
this VAAR have been approved by OMB and have

[[Page 139]]

been given the following approval numbers:

                                                                        
------------------------------------------------------------------------
                                                           Current OMB  
 48 CFR part or section where identified and described     control No.  
------------------------------------------------------------------------
809.504(d).............................................        2900-0418
819.7003...............................................        2900-0445
836.606-71.............................................        2900-0422
852.236-72.............................................        2900-0422
852.236-79.............................................        2900-0422
852.236-81 through 852.236-85..........................        2900-0422
852.236-88.............................................        2900-0422
871.201-2..............................................        2900-0416
------------------------------------------------------------------------

[49 FR 12583, Mar. 29, 1984, as amended at 50 FR 790, Jan. 7, 1985; 54 
FR 31962, Aug. 3, 1989; 54 FR 40062, Sept. 29, 1989]



801.303  Codification and public participation.

    The VAAR is codified as chapter 8 of title 48, Code of Federal 
Regulations. Codified changes to the VAAR will be published in the 
Federal Register. The Deputy Assistant Secretary for Acquisition and 
Materiel Management arranges distribution of the issues to VA 
contracting activities and the Office of Acquisition and Materiel 
Management should be notified of changes to the distribution list.
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 31962, Aug. 3, 1989]



801.304  Department control and compliance procedures.

    Office of Acquisition and Materiel Management is responsible for 
ensuring that the VAAR and amendments thereto are developed as 
prescribed by the FAR.
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 31962, Aug. 3, 1989]



             Subpart 801.4--Deviations From the FAR or VAAR



801.403  Individual deviations.

    (a) When contracting officers consider it necessary to deviate from 
the policies set forth in the FAR or VAAR, a request for authority to do 
so will be submitted to the Deputy Assistant Secretary for Acquisition 
and Materiel Management (93). The request will clearly set forth the 
circumstances warranting the deviation and nature of the deviation.
    (b) When a deviation in an individual case is authorized by the 
Deputy Assistant Secretary for Acquisition and Materiel Management, the 
authorization will be filed in the purchase or contract file, whichever 
is appropriate.
[54 FR 31962, Aug. 3, 1989, as amended at 61 FR 20491, May 7, 1996]



801.404  Class deviations.

    The Deputy Assistant Secretary for Acquisition and Materiel 
Management is responsible for determining the need for class deviations. 
If determined necessary, the Deputy Assistant Secretary for Acquisition 
and Materiel Management will request deviation authority from the Deputy 
Secretary through the Senior Procurement Executive as well as complying 
with the provisions in FAR 1.404.
[49 FR 12583, Mar. 29, 1984, as amended at 52 FR 49016, Dec. 29, 1987; 
54 FR 31962, Aug. 3, 1989]



        Subpart 801.6--Contracting Authority and Responsibilities



801.601  General.

    (a) This subpart establishes general contracting officer authority 
and responsibility. However, other provisions in both the FAR and the 
VAAR contain some contracting officer limitations and it is incumbent 
upon each contracting officer to be aware of those limitations.
    (b) Personnel, other than those designated in 801.602, may determine 
quality, quantity and delivery requirements for items or services to be 
purchased. However, under no circumstances will individuals who have not 
been delegated contracting authority commit the Government for purchases 
of supplies, equipment or services. Individuals making such commitments 
may be held financially liable for the amount of the obligation.



801.602  Contracting officers.

    (a) Except as otherwise provided by law, VA regulations, VAAR and 
FAR, the authority vested in the Secretary to do the following is 
delegated to the Senior Procurement Executive and is further delegated 
to the Procurement Executive:
    (1) Execute, award, and administer contracts, purchase orders, and 
other

[[Page 140]]

agreements (including interagency agreements) for the expenditure of 
funds involved in the acquisition of personal property, service 
(including architect-engineer services), construction, issuing 
Government bills of lading, and for the sale of personal property, 
leases, sales agreements and other transactions;
    (2) Prescribe and publish acquisition policies and procedures;
    (3) Establish clear lines of contracting authority;
    (4) Manage and enhance career development of the procurement work 
force;
    (5) Examine, in coordination with the Office of Federal Procurement 
Policy, the procurement system to determine specific areas where 
Governmentwide performance standards should be established and applied, 
and to participate in the development of Governmentwide procurement 
policies, regulations and standards; and,
    (6) Oversee the competition advocate program.
    (b) Further delegation to execute, award, and administer contracts, 
purchase orders and other agreements will be made in accordance with the 
Contracting Officer Certification Program as prescribed in (VAAR) 48 CFR 
801.670 and 801.690.
[61 FR 1526, Jan. 22, 1996]



801.602-2  Responsibilities.

    (a) In the administration of a contract, many problems can and do 
arise that make the advice and assistance of the General Counsel either 
desirable or necessary. The final decision as to the action to be taken, 
however, must be made by the contracting officer in each instance. To 
reduce to the absolute minimum the possibility of litigation resulting 
from his/her decision, the contracting officer shall, except as provided 
in paragraph (c) of this section, submit the problem through channels in 
sufficient detail to the General Counsel for advice or assistance.
    (b) While legal review and concurrence of the General Counsel is 
required prior to a default termination, in some cases where a quick 
response is necessary, this review can be expedited by express mailing 
or telefaxing the default letter and related documents which are 
required to make an evaluation directly to the General Counsel (025). 
The default termination letter should contain, at a minimum, the 
following:
    (1) The proposed termination (FAR 49.102);
    (2) An explanation of what necessitated the default, including the 
reasons why the contracting officer considers the contractor to be in 
default;
    (3) A statement that the factors set forth in FAR 49.402-3(f) have 
been fully considered; and
    (4) Final decision language and appeal rights.
    (c) Contracts containing a mutual termination clause may be 
terminated without reference to the General Counsel.
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 31962, Aug. 3, 1989]



801.602-3  Ratification of unauthorized commitments.

    (a) Contracting officers shall not ratify contractual commitments 
made by other VA personnel without prior approval as prescribed below. 
Such unauthorized commitments include commitments made by other 
contracting officers which exceed their respective contracting authority 
as well as unauthorized commitments made by individuals lacking 
contracting authority.
    (1) At field stations, for supplies, services and construction, the 
approving authority is the director of the field facility concerned.
    (2) For central office contracting officers, for supplies, and 
services and construction, the approving authorities are the heads of 
the administrations and directors of the staff offices concerned, and 
the Deputy Assistant Secretary for Acquisition and Materiel Management.
    (3) For acquisitions of leasehold interest in real property the 
approving authority is:
    (i) The Chief Facilities Management Officer, Office of Facilities 
Management, for 1-5,000 square feet, and for 1-100 parking spaces 
costing less than $50,000 per annum.
    (ii) The Assistant Secretary for Management for 5,001-20,000 square 
feet, and for parking spaces exceeding 100 which cost less than $100,000 
per annum.

[[Page 141]]

    (iii) The Deputy Secretary for 20,001 square feet and above, and for 
parking spaces exceeding 100 which cost more than $100,000 per annum.
    (4) This approval authority shall not be redelegated.
    (b) Requests received by contracting officers for ratification of 
commitments made by personnel lacking contracting authority shall be 
processed as follows:
    (1) The individual who made the unauthorized contractual commitment 
shall furnish the contracting officer all records and documents 
concerning the commitment and a complete written statement of facts, 
including, but not limited to, a statement as to why the procurement 
office was not utilized, why the proposed contractor was selected and a 
list of other sources considered, description of work to be performed or 
products to be furnished, estimated or agreed contract price, citation 
of appropriation available, and a statement of whether the contractor 
has commenced performance.
    (2) The contracting officer will review the file and forward it to 
the approving authority specified in paragraph (a) of this section with 
any comments or information which should be considered in evaluation of 
the request for ratification. If legal review is desirable, the 
approving authority will coordinate the request for ratification with 
the Office of General Counsel or the District Counsel, as appropriate.
    (3) If ratification is authorized, the file will be returned to the 
contracting officer for issuance of a purchase order or contract, as 
appropriate.
    (c) In the case of otherwise proper contract awards made by 
contracting officers in excess of the limits of their delegated 
authority, the need for ratification will be brought to the attention of 
the head of the contracting activity. That individual will take such 
action as may be indicated to preclude future instances of such awards.
[54 FR 31962, Aug. 3, 1989, as amended at 61 FR 11585, Mar. 21, 1996]



801.602-70  Legal/technical review requirements to be met prior to contract execution.

    (a) The following categories of proposed contracts and agreements 
will be reviewed and concurred in by the Office of Acquisition and 
Materiel Management prior to contract execution. (Additionally, the 
Office of Acquisition and Materiel Management may, when considered 
necessary, request preaward technical review regardless of dollar 
value). Office of General Counsel legal reviews of such proposed 
contracts and agreements will be performed when requested and determined 
necessary by the Office of Acquisition and Materiel Management. 
(Excluded from this requirement is the National Acquisition Center which 
will perform its own technical reviews at the thresholds herein 
prescribed. The National Acquisition Center will receive preaward legal 
review of solicitation from the General Counsel staff located in Hines, 
Illinois).
    (1) All negotiated and sealed bid contracts (except as specified in 
(a)(2) and (a)(3)) exceeding $250,000 in either appropriated or 
nonappropriated funds. This includes indefinite quantity contracts when 
expenditures of $250,000 or more can reasonably be expected, and 
multiyear contracts in which $250,000 or more will be expended over the 
life of the contract. (Note also that multiyear contracts also require 
review any time the cancellation ceiling exceeds 20 percent of the 
contract amount (see 817.1)).
    (2) All fixed price, sealed bid construction contracts involving 
$500,000 or more in either appropriated or unappropriated funds.
    (3) All 8(a) contracts exceeding $500,000.
    (4) All proposed agreements and contracts coming within the purview 
of one or more of the following:
    (i) Contracts for insurance.
    (ii) Utility service agreements involving $50,000 or more.
    (iii) Contracts for consulting services (see subpart 837.2) and 
management and professional services (see 837.271).
    (iv) Contracts for research or research and development involving 
$50,000 or more.
    (v) Automatic data processing equipment, when purchased from other 
than a Federal Supply Schedule contract, involving $50,000 or more.
    (vi) Competitive contracts exceeding $50,000 and noncompetitive 
contracts

[[Page 142]]

exceeding $200,000, for scarce medical specialist services.
    (vii) Competitive contracts exceeding $50,000 and noncompetitive 
contracts exceeding $200,000 for the mutual use, or exchange of use, of 
specialized medical resources.
    (viii) Agreements with other Federal agencies regardless of dollar 
value. Those agreements of $5,000 or more will be forwarded to General 
Counsel for legal review. VA/DoD Sharing Agreements executed under the 
authority of Public Law 97-174 (38 U.S.C. 8111) and sections 201-206 of 
Public Law 102-585 are exempt from review by the Office of Acquisition 
and Materiel Management; however, they must be approved in accordance 
with VA Manual M-1, Part I, Chapter 1, Section XI.
    (ix) Contracts for ADP software exceeding $10,000.
    (x) ADP software licensing agreements for ADP software exceeding 
$10,000 (all software licensing agreements require technical review).
    (5) All proposed letter contracts and ensuing formal contracts 
involving expenditures of $5,000 or more.
    (6) Any proposed agreement that is unique, novel or unusual 
(including all consignment agreements, regardless of anticipated dollar 
value--except those established and provided in Federal Supply Schedule 
Contracts).
    (7) Step One of two-step sealed bid procurements when the 
anticipated value is more than $200,000.
    (b) The following categories of proposed contractual actions require 
the concurrence of the General Counsel:
    (1) Contract modifications, terminations (including final decision 
(cure) letters), disputes and claims in excess of $25,000 ($50,000 for 
contracts awarded by the Office of Facilities Management).
    (2) Contract modifications granting a time extension of more than 20 
days.
    (3) Assignment of claims.
    (4) Proposed awards to other than the low evaluated bidder/offeror.
    (c) In addition to the requirements of paragraphs (a) and (b) of 
this section, the following require review and concurrence of the 
General Counsel:
    (1) Changes or revisions to all contract clauses.
    (2) Changes or revisions to prescribed VA contract forms.
    (d) Utility construction and connection contracts which are 
developed in the Office of Facilities Management and cost $50,000 or 
more will be be reviewed by General Counsel and the Chief Facilities 
Management Officer, Office of Facilities Management.
    (e) When legal assistance is requested by any Central Office 
contracting activity, the contracting officer will brief the General 
Counsel regarding the facts and points of issue to facilitate prompt 
resolution.
    (f) With regard to solicitations and contracts awarded and 
administered by the Central Office contracting activities, the General 
Counsel will be requested to participate in conferences where it is 
expected that legal problems or contract provisions will be considered, 
and in meetings attended by legal representatives of private parties or 
other Government agencies. Assigned procurement counsel will be 
requested to participate in the drafting of correspondence involving 
controversial or sensitive contractual matters of a significant nature.
    (g) All protests against award will be reviewed by General Counsel 
in accordance with the provisions specified in 48 CFR 833.103.
    (h) Excluded from these legal review requirements are:
    (1) Agreements, licenses, easements, or deeds dealing with 
management, sale, or lease of properties acquired by VA as a result of 
liquidation of guaranteed, direct, acquired or vendee loans.
    (2) Orders or contracts for procurement of leased telecommunications 
systems, installation of and changes to telephone PBX systems at 
individual Department of Veterans Affairs locations or orders issued 
under GSA area-wide contracts with the American Telephone and Telegraph 
Company and local telephone companies.
    (i) If a change order (unilateral agreement) is essential for the 
logical process of the contract, the Office of Acquisition and Materiel 
Management, Acquisition Review Division shall be called prior to issuing 
the document. (This requirement does not apply to change orders issued 
by the Office of Facilities Management.)

[[Page 143]]

    (j) The following apparent low responsive and responsible bids/
offers with the respective solicitations will be submitted for the 
review of the Deputy Assistant Secretary for Acquisition and Materiel 
Management, Acquisition Review Division, prior to award:
    (1) Negotiated contract actions in the Office of Facilities 
Management which exceed $2 million.
    (2) Bids/offers for construction contracts to be awarded by VHA 
facilities which exceed $5 million.
    (3) Bids/offers for service contracts, including A/E, which exceed 
$2 million, and
    (4) Bids/offers for supply contracts which exceed $5 million in 
total evaluated cost (excluding FSS contracts awarded by VA National 
Acquisition Center).
[49 FR 12583, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985; 51 
FR 23066, June 25, 1986; 52 FR 28559, July 31, 1987; 52 FR 49016, Dec. 
29, 1987; 54 FR 31963, Aug. 3, 1989; 55 FR 31391, Aug. 2, 1990; 58 FR 
31914, June 7, 1993; 61 FR 11585, Mar. 21, 1996]



801.602-71  Processing contracts for legal/technical review.

    (a) All competitively awarded solicitations requiring legal and/or 
technical review will have such reviews completed prior to opening of 
bids or proposals. The contracting officer will fully evaluate technical 
and legal review comments prior to opening bids or proposals. Potential 
bidders/offerors will be advised of changes to the solicitation by 
amendment and afforded sufficient time for evaluation prior to opening 
of bids or offers.
    (b) Veterans Health Administration (VHA) Field Facilities, VA 
National Acquisition Center. (1) Proposed contracts or agreements 
specified in 801.602-70(a) (1), (2), (3), (4) (iii) through (v), (5), 
(6) and (7) will be forwarded by the contracting officer directly to the 
Deputy Assistant Secretary for Acquisition and Materiel Management, 
Acquisition Review Division. The Deputy Assistant Secretary for 
Acquisition and Materiel Management will review the submissions and when 
applicable, forward them directly to the General Counsel (025).
    (2) Proposed sharing agreements and contracts for specialized 
medical services specified in 801.602-70(a)(4) (vi) and (vii) will be 
forwarded to Central Office in accordance with 815.7001 for review and 
submission to the General Counsel (025).
    (3) Proposed interagency agreements specified in 801.602-
70(a)(4)(viii) will be forwarded by the approving official to the Deputy 
Assistant Secretary for Acquisition and Materiel Management, Program 
Development and Evaluation Division. The Deputy Assistant Secretary for 
Acquisition and Materiel Management will review the submissions and 
forward them directly to the General Counsel (025).
    (4) Proposed facility-level modification specified in 801.607-70(b) 
will be forwarded by the contracting officer to General Counsel (025), 
through the Deputy Assistant Secretary for Acquisition and Materiel 
Management, Acquisition Review Division.
    (5) Proposed final decisions or settlement agreements specified in 
801.602-70(b) will be forwarded by the contracting officer directly to 
the Deputy Assistant Secretary for Acquisition and Materiel Management. 
The Deputy Assistant Secretary for Acquisition and Materiel Management 
will review the submissions and forward them to the General Counsel 
(025).
    (6) Proposed revisions to contract clauses specified in 801.602-
70(c) will be forwarded by the contracting officer directly to the 
Deputy Assistant Secretary for Acquisition and Materiel Management. If 
concurred in, the Deputy Assistant Secretary for Acquisition and 
Materiel Management will forward them directly to the General Counsel.
    (c) Veterans Benefits Administration field facilities. (1) All 
proposed State reimbursement contracts and Guidance Center and 
Vocational Rehabilitation contracts which are anticipated to ultimately 
involve the expenditure of $100,000 or more, will be forwarded by the 
contracting officer directly to the Director, Vocational Rehabilitation 
and Education Service, for review and approval. The Director, Vocational 
Rehabilitation and Education Service will review the submissions and 
forward them to the General Counsel.
    (2) Any other proposed agreement or contract specified in 801.602-
70(a) will

[[Page 144]]

be forwarded by the facility Director to the Chief Benefits Director for 
Field Operations (201) for coordination with Director(s) of the 
concerned service(s) and submission to the General Counsel.
    (3) Any other element of contracting falling within 801.602-70 (b) 
and (c) will be processed in accordance with paragraph (b)(2) of this 
section.
    (d) Central office. Any element of contracting prescribed for legal 
review in 801.602-70 originating in central office, will be submitted 
for legal review by the contracting officer, or approving official in 
the case of agreements with other Government agencies through the Deputy 
Assistant Secretary for Acquisition and Materiel Management, Acquisition 
Review Division. (Except that in the case of Office of Facilities 
Management contracts, a selected sample of contracts will be processed 
through the Office of Acquisition and Materiel Management, Acquisition 
Review Division. All other Office of Facilities Management contract 
actions identified in 801.602-70 will be sumitted for legal review in 
accordance with Office of Facilities Management procedures).
    (e) All bids/offers required to be reviewed prior to award in 
accordance with 801.602-70(j), will be forwarded to the Deputy Assistant 
Secretary for Acquisition and Materiel Management, Acquisition Review 
Division, with a cover letter identifying:
    (1) The date in which the award is anticipated;
    (2) Responsibility determination results or efforts ongoing;
    (3) Determinations of price reasonableness;
    (4) Explanation of proposed award to other than low responsible 
bidder/offeror.
[49 FR 12583, Mar. 29, 1984, as amended at 52 FR 28559, July 31, 1987; 
52 FR 49017, Dec. 29, 1987; 54 FR 31963, Aug. 3, 1989; 54 FR 40062, 
Sept. 29, 1989; 61 FR 11585, Mar. 21, 1996]



801.602-72  Documents to be submitted for legal review.

    The following documents are to be submitted for legal review:
    (a) For proposed construction contracts, one copy of all 
solicitation documents, excluding drawings. These documents will be 
submitted no later than at the time they are furnished to prospective 
bidders. Where feasible, these documents should be submitted for review 
prior to the time they are furnished to prospective bidders.
    (b) For sharing agreements and scarce medical specialist contracts, 
the documents referred to in 815.7001.
    (c) For all other proposed contracts and agreements, a copy of the 
documents to be used in the solicitation and/or award of contract, 
including any other documents which support the proposed procurement 
action, e.g., justification and approval in the case of noncompetitive 
procurement. Solicitation documents will be submitted no later than at 
the time they are mailed to prospective bidders. Where feasible, these 
documents should be submitted for review prior to the time they are 
mailed to prospective bidders.
    (d) For contract modifications described in 801.602-70(b) and 
801.602-71(b)(4) and (d):
    (1) A draft of the proposed modification. This shall be prepared on 
an SF (Standard Form) 30, Amendment of Solicitation/Modification of 
Contract, and shall specify the exact language to be used. Changes in 
work, time and cost must be specifically described;
    (2) A statement describing the need for the changed work. This 
should also be accompanied by any backup documentation, including a copy 
of the general statement of work in the original contract plus any 
existing contract language which will be modified. Include a statement 
that the work covered by the proposed modification is or is not within 
the original scope of the contract, setting forth fully the facts 
considered in reaching the conclusion;
    (3) A statement containing an analysis on what necessitated the 
modification, e.g., design error, technical change, medical center 
requirements;
    (4) The contracting officer's technical representative (COTR) 
technical evaluation of the proposed change;
    (5) For construction modifications and, where applicable for 
architect-engineer (A/E) modifications, a copy of drawings which the 
COTR has marked up to delineate the proposed changed work. If 
appropriate, include a copy of the pertinent technical specifications.

[[Page 145]]

Whenever a proposed contract modification involves numerous changes to 
drawings and specifications for a Central Office project, the drawings 
and specifications will be available for review in the office of the 
Project Director;
    (6) Costing information including:
    (i) The contractor's cost proposal in the format required by the 
contract.
    (ii) The COTR's independent cost evaluation.
    (iii) The A/E's independent cost evaluation.
    (iv) Contracting officer's Price Negotiation Memorandum (PNM) in 
accordance with VAAR 815.808. For Office of Facilities Management 
contracts, the PNM may be submitted by either the contracting officer or 
COTR.
    (v) For A/E contracts, a listing of the fees awarded in the original 
contract and previous modifications.
    (vi) For A/E working drawing contracts, a statement regarding the 
actual or estimated cost of the original construction and any estimated 
change to the overall project cost as a result of the proposed 
modification.
    (vii) Any other relevant costing information, such as independent 
market research, which was or will be used as negotiation criteria.
    (7) A concurrence on the memorandum from the appropriate office 
indicating that funds are available or a statement concerning the 
actions which must be taken to secure the required funds; and
    (8) The names and telephone numbers of the contracting officer and 
COTR.
    (e) For bids/offers submitted as required by 801.602-70(j), the 
following documents will be provided:
    (1) Request for contract action, including justification of need.
    (2) The solicitation.
    (3) Abstracts of bids/offers.
    (4) Price negotiations memorandum, if applicable.
    (5) Justification and approval (see FAR 6.303), if applicable.
    (6) Documents relevant to determination of contractor's 
responsibility.
    (7) Documents relevant to price reasonableness.
[49 FR 12583, Mar. 29, 1984, as amended at 51 FR 23066, June 25, 1986; 
52 FR 28559, July 31, 1987; 52 FR 49017, Dec. 29, 1987; 54 FR 31964, 
Aug. 3, 1989; 54 FR 40062, Sept. 29, 1989; 61 FR 11586, Mar. 21, 1996; 
61 FR 20491, May 7, 1996]



801.602-73  Certification by reviewing official.

    In submitting proposed agreements or contracts received from field 
stations to the General Counsel, the Central Office reviewing officials 
will state on the transmittal memorandum or within the file that the 
proposal conforms to the Federal Acquisition Regulations and Department 
of Veterans Affairs Acquisition Regulations to the best of their 
knowledge.
[49 FR 12583, Mar. 29, 1984, as amended at 61 FR 11586, Mar. 21, 1996]



801.602-74  Results of General Counsel's legal review.

    (a) Upon completion of the review, the General Counsel will advise 
the appropriate Central Office activity or contracting officers as to 
whether the proposal was approved as submitted or provide them with the 
recommended changes. The appropriate Central Office activity will advise 
the contracting officer as to whether: (1) The submission was approved 
as is, or (2) provide a copy of the changes required. Where changes are 
required, the contracting officer will take immediate action to amend 
the solicitation document.
    (b) The General Counsel's review will be completed as expeditiously 
as possible, with due regard to those procurement actions where 
circumstances dictate an unusually short period for completing 
procurement action.



801.603  Selection, appointment, and termination of appointment.



801.603-1  General.

    The policy and procedures for the selection, appointment, and 
termination of appointment of contracting officers are established in 
VAAR 801.690, The

[[Page 146]]

Contracting Officer Certification Program, and as otherwise provided in 
VAAR 801.670 and its subsections.
[52 FR 24010, June 26, 1987]



801.603-70  Representatives of contracting officers.

    (a) In carrying out the responsibilities of FAR 1.602-2, the 
contracting officer may designate another Government contracting 
officer, or other Government employees, or another contractor:
    (1) To furnish technical guidance and advice or generally supervise 
the work performed under the contract. Such designations will be in 
writing and will define the scope and limitation of the representative's 
authority; and, will be addressed to the designee with a copy to be 
forwarded to the contractor except as indicated in 801.603-71. Except as 
provided in paragraph (c) of this section representatives will not be 
authorized to make any commitments or changes which will affect the 
price, quantity, quality or delivery terms. (All changes to a contract 
must be authorized by a contracting officer acting within the scope of 
his/her authority.)
    (2) To take actions authorized in the contract, such as issue 
delivery orders, reject unsatisfactory items, order replacement of such 
items (materials or services) and, when necessary, declare contractor in 
default on specific delivery orders. Except for blood, this authority 
will be delegated only to other Government contracting officers under 
centralized indefinite delivery type contracts and the contract will so 
state. Centralized contracts for blood will provide that contracting 
officers at ordering offices are authorized to designate representatives 
and alternate representatives to place delivery orders subject to the 
same restrictions stated in paragraph (a)(3) of this section.
    (3) To place oral or other informal delivery orders for items such 
as, but not limited to, bread, milk, and blood against local indefinite 
delivery type contracts on which blanket purchase arrangements have been 
established and funds have been obligated. The designation of 
representatives and alternates will be in writing and will define the 
scope and limitations of the representative's authority, and will be 
addressed to the employee(s) with a copy to the contractor. Such 
designations will be made only by the prime contracting officer and are 
not redelegable.
    (b) In the administration of research and development contracts, any 
representative appointed pursuant to this section must be acceptable 
both to the contracting officer and the administration head or staff 
office director concerned. When it is necessary to designate a 
representative under this paragraph (b), the clause in 852.270-1 will be 
observed.
[49 FR 12583, Mar. 29, 1984, as amended at 52 FR 24010, June 26, 1987; 
54 FR 40062, Sept. 29, 1989]



801.603-71  Representatives of contracting officers; receipt of equipment, supplies, and nonpersonal services.

    (a) Except as provided in paragraphs (b), (c) and (d) of this 
section, any contracting officer may, without prior notification to the 
contractor or vendor, designate the Chief, Storage and Distribution 
Section, or other competent personnel, to represent him/her in receiving 
and inspecting supplies, equipment and services at his/her facility. 
Duties such as, but not limited to, the following will be performed by 
these designees:
    (1) The inspection and certification as to compliance with the 
quality and quantity requirements of the purchase order or contract; and
    (2) Inspection of supplies and equipment for condition and quantity 
and the acceptance of supplies, equipment, and services, based on 
quality inspection made by other authorized representatives.
    (b) The Chief, Central Office Library Division, and the Chief, 
Library Service, at a field facility, are designated the representatives 
of the contracting officer to receive, inspect and accept library books, 
newspapers, and periodicals. Purchase documents will specify that 
delivery will be made direct to the library.
    (c) The Chief, Stock Control Division, VA Supply Depot, Hines, Ill., 
is hereby designated as the representative of each contracting officer 
and

[[Page 147]]

purchasing agent of the various marketing divisions of the VA National 
Acquisition Center, Hines, Ill., for the purpose of accepting, on behalf 
of the Department of Veterans Affairs, items purchased for stock. The 
Chief, Stock Control Division, may designate one or more employees of 
the Incoming Property Section, Supply Control Division, to represent 
him/her and authority is hereby delegated to such designees to accept 
such property on behalf of the Department of Veterans Affairs. 
Designations will be confined to those employees to whom such 
responsibility has been assigned by their position descriptions. The 
Chief, Fiscal Service, will be furnished a list of such designees. Where 
inspection for compliance with specifications, purity, quality, or other 
element must be made by the Service and Reclamation Division or other 
testing agency, acceptance will be contingent upon receipt of a properly 
prepared inspection report.
    (d) The Chiefs, Service and Reclamation Divisions, Department of VA 
Supply Depots at Hines, Ill., Somerville, N.J., and Bell, Calif., are 
hereby designated as the respresentatives of the contracting officers 
and purchasing agents of the various marketing divisions of the Veterans 
Affairs National Acquisition Center, Hines, Ill., for the purpose of 
inspecting, when requested, supplies and equipment for compliance with 
technical, mechanical, operating, and other specifications. The results 
of such inspections will be forwarded to the Chief, Stock Control 
Division, VA Supply Depot, Hines, IL 60141, when the item(s) involved is 
for stock, and to the appropriate contracting officer or purchasing 
agent for all other items.
    (e) The Chief of each Service and Reclamation Division may designate 
one or more employees of his/her division to represent him/her; and, 
authority is hereby delegated to such designees to perform the 
inspection functions set forth in paragraph (d) of this section. 
(Designations shall be in writing with a copy furnished to the Associate 
Deputy Assistant Secretary for the National Acquisition Center, Hines, 
Ill. Designations will remain in effect unless revoked. The reassignment 
or termination of either the designee or the Chief, Service and 
Reclamation Division, issuing the designation will serve as an automatic 
rescission of the designation.)
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 31964, Aug. 3, 1989; 54 
FR 40062, Sept. 29, 1989; 61 FR 11586, Mar. 21, 1996]



801.670  Special and limited delegation.

    The authority vested in the Secretary to execute, award and 
administer contracts, purchase orders and other agreements for the 
expenditure of funds involved in the acquisition of the specific 
services set forth in this 801.670 and its subsections, is hereby 
delegated to the Senior Procurement Executive for further delegation to 
those employees appointed or designated to the positions specified in 
these subsections.
[49 FR 12583, Mar. 29, 1984, as amended at 54 FR 31964, Aug. 3, 1989]



801.670-1  Issue of Government bills of lading--transportation of remains of deceased beneficiaries.

    The Chief, Medical Administration Service, at a Department of 
Veterans Affairs medical center, or the person acting in that capacity, 
is delegated authority to issue and to sign as ``Issuing Officer,'' 
Government bills of lading for the shipment of the remains of 
beneficiaries expiring in a Department of Veterans Affairs medical 
center.
[49 FR 12583, Mar. 29, 1984. Redesignated at 52 FR 24010, June 26, 1987]



801.670-2  Issue of Government bills of lading--transportation of property.

    (a) Authority to issue and sign Government bills of lading for the 
transportation of supplies, material, and equipment is delegated to the 
following:
    (1) Chiefs, Transportation Sections, VA Supply Depots.
    (2) Chief, Warehouse Section, VA Forms and Publications Depot.
    (3) Traffic Manager, Office of Acquisition and Materiel Management, 
Central Office.
    (b) The employees named in paragraph (a) of this section may 
designate one or more of their subordinates as a contracting officer; 
and, authority is hereby delegated to such subordinates to issue and 
sign Government bills of

[[Page 148]]

lading for the transportation of supplies, material, and equipment. 
Designations will be in writing and specifically set forth the scope and 
limitation of the designee's authority.
[49 FR 12583, Mar. 29, 1984. Redesignated at 52 FR 24010, June 26, 1987, 
and amended at 54 FR 31964, Aug. 3, 1989; 54 FR 40062, Sept. 29, 1989]



801.670-3  Medical, dental, and ancillary service.

    (a) The Chief of Staff, the physician assigned the responsibility 
for the ambulatory care function, and Chief, Medical Administration 
Service, at a Department of Veterans Affairs facility are delegated 
authority to execute authorizations for medical, dental, and ancillary 
services under $10,000 per authorization when such services are not 
available from existing contracts or agreements. Forms specified in part 
853 of this chapter will be used for this purpose and when ordering such 
services from existing contracts.
    (b) The contracting officers named in paragraph (a) of this section 
may designate one or more of their subordinates to execute the forms for 
purposes stated in paragraph (a) of this section. Designations will be 
in writing and will specifically set forth the scope and limitations of 
the designee's authority.
[49 FR 12583, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985. 
Redesignated at 52 FR 24010, June 26, 1987, and further amended at 54 FR 
31964]



801.670-4  National Cemetery System.

    Authority for the National Cemetery System to procure supplies, 
equipment and nonpersonal services is delegated as follows:
    (a) Authority to issue and sign Government bills of lading for the 
transportation of headstones and markers is further delegated to:
    (1) Chief, Acquisition Division, Monument Service.
    (2) Chief, Transportation Section, Monument Service and Freight Rate 
Specialist.
    (b) Authority to procure, in emergency situations when the servicing 
supply organization cannot be utilized, and in accordance with the 
provisions of FAR Part 13, supplies, equipment, and nonpersonal services 
(including construction) required for the operation of national 
cemeteries is delegated to:
    (1) Director, National Cemetery System, and Deputy Director, 
National Cemetery System.
    (2) Director and Deputy Director, National Cemetery Area Office.
    (c) Authority to procure items and nonpersonal services up to $300 
per transaction for the operation of national cemeteries is delegated to 
the Director of each national cemetery. The authority is to be used only 
in emergency situations when the servicing supply organization cannot be 
utilized, and the method of purchase is limited to the use of SF 44, 
Purchase Order--Invoice--Voucher, (FAR 13.505-3).
[49 FR 12583, Mar. 29, 1984. Redesignated and amended at 52 FR 24010, 
June 26, 1987; 54 FR 31964, Aug. 3, 1989]



801.670-5  Letters of agreement.

    (a) Authority to execute, award, and administer letters of agreement 
(subject to the limitation prescribed in 837.2) is delegated to the 
following:
    (1) General Counsel.
    (2) Deputy Assistant Secretary for Human Resources Management.
    (3) Chief Medical Director.
    (4) Chief Benefits Director.
    (5) Chief Memorial Affairs Director.
    (6) Deputy Assistant Director for Acquisition and Materiel 
Management
    (7) Inspector General.
    (8) Directors, Regional Medical Education Centers (limited to 
obtaining instructors and training pursuant to section 4122 of Title 38, 
United States Code).
    (9) Directors, Domiciliary and Medical Centers and Research and 
Development Service Directors authorized to sign for the Assistant Chief 
Medical Director for Research and Development (limited to obtaining peer 
review of research (see 837.2)).
    (b) The contracting officers named in paragraphs (a) (1) through (7) 
of this section may designate one or more subordinates, and authority to 
execute the same duties and responsibilities is hereby delegated to such 
subordinates. Such subordinates will be no more than one organizational 
level below the contracting officers designated in paragraph (a) of this 
section, except that

[[Page 149]]

the Under Secretary for Health may designate the Veterans Integrated 
Service Network Directors. All such designations will be in writing, 
will specifically state the scope and limitations of the designees' 
contractual authority, and will also specifically prohibit further 
delegation by the designees. Copies of the delegation will be submitted 
to the Office of Acqusition and Materiel Management, Acquisition Review 
Division.
    (c) Copies of all letters of agreement issued by the designees 
identified in paragraphs (a) and (b) of this section will be forwarded 
to the servicing contracting activity in order that the procurement 
action may be entered into the Federal Procurement Data System.
[49 FR 12583, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985. 
Redesignated at 52 FR 24010, June 26, 1987, and further amended at 54 FR 
31964, Aug. 3, 1989; 54 FR 40062, Sept. 29, 1989; 61 FR 11586, Mar. 21, 
1996]



801.680  Contracting authority of the Inspector General.

    (a) As provided by section 6(a) of Pub. L. 95-452 (October 12, 
1978), the Inspector General is authorized to enter into contracts and 
other arrangements for audits, studies, analyses, and other services 
with public agencies and with private persons, and to make such payments 
as may be necessary to carry out the provisions of the Act, to the 
extent and in such amounts as may be provided in advance by 
appropriations Acts.
    (b) In exercising the special authority provided in paragraph (a) of 
this section, the Inspector General may request the assistance of the 
servicing Acquisition and Materiel Management Service in developing 
appropriate contract or agreement documents.
    (c) If, in the opinion of the Inspector General, a reason to 
exercise the special authority does not exist, the services required by 
the Inspector General shall be obtained by the servicing Supply Service 
in accordance with the provisions of FAR and VAAR.
    (d) Contracts entered into under the authority of paragraph (a) of 
this section are subject to the provisions of the Federal Acquisition 
Regulations. In addition, such contracts are subject to those provisions 
of VAAR which implement and supplement the FAR on matters other than 
those stemming from or related to delegations of the Secretary's 
contracting authority (e.g., management controls and approvals specified 
in subpart 837.2 will not apply to contract actions under the contract 
authority of the Inspector General).
[49 FR 12583, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985; 54 
FR 31964, Aug. 3, 1989; 61 FR 11586, Mar. 21, 1996]



801.690  VA Contracting Officer Certification Program.

    The policy and procedures for the VA-wide Contracting Officer 
Certification Program (COCP) are established in this section and 
subsections.
[52 FR 24010, June 26, 1987]



801.690-1  Definitions.

    (a) Head of the Contracting Activity (HCA) means an individual who 
has overall responsibility for managing the procurement program assigned 
to the activity. HCA designations are prescribed in VAAR 802.100. The 
HCA has the authority to appoint contracting officers with authority to 
conduct procurements of up to and including $25,000 or the maximum order 
limitation for orders placed against established contracts, and 
terminate such appointments.
    (b) Recommending official means an individual who is authorized by 
VAAR 801.690 and its subsections to recommend to a designating official 
that an individual be appointed as a contracting officer.
    (c) Designating official means an individual who is authorized to 
appoint and terminate contracting officers.
    (d) Contracting Officer Certification Board (COCB) means the group 
of Department officials, listed in VAAR 801.690-3(c), that evaluates and 
recommends to the designating official individuals as contracting 
officers at the Intermediate and Senior levels of authority, which 
levels are described in VAAR 801.690-2(c).
    (e) Contracting Officer Certification Program (COCP) means a program 
designated by Department management

[[Page 150]]

for the selection, appointment, and termination of appointment of 
contracting officers. Training, experience, education, performance, and 
conduct are the objective criteria reviewed prior to appointment as 
contracting officer.
    (f) Qualifications means an employee's record of training, 
experience, education, performance, and conduct which are reviewed prior 
to designation as contracting officer. These ``qualifications'' are not 
identical, supplemental, or related to the position qualification 
requirements published by the Office of Personnel Management in Handbook 
X-118.
    (g) Appointment means the delegation of authority to any employee to 
enter into, administer or terminate contracts, and make related 
determinations and findings. Appointment provisions are identified in 
801.690-5.
    (h) Certification means an evaluation that the candidate has the 
experience, education and training to perform properly the duties of a 
contracting officer.
    (i) Selection means that an employee has been appointed or certified 
as a contracting officer. The ``selection'' process is not identical, 
supplemental or related to any process whereby an employee is placed 
into a position by any competitive action (merit promotion) or 
noncompetitive action (reassignment, reinstatement). Selection 
provisions are identified in 801.690-4.
    (j) Termination means the revocation of contracting authority of a 
contracting officer by the designating official. Termination provisions 
are identified in 801.690-6.
    (k) Acquisition Training Program (ATP) means a program designed to 
provide contracting officers with classroom knowledge to further develop 
their acquisition skills.
[52 FR 24010, June 26, 1987, as amended at 54 FR 31964, Aug. 3, 1989; 54 
FR 40062, Sept. 29, 1989]



801.690-2  General.

    (a) The VA COCP applies to all programs of the Department of 
Veterans Affairs except for those contracting officers appointed 
pursuant to the Inspector General Act (Pub. L. 95-452).
    (b) A certification of appointment is not required for contracting 
officers designated in 801.670 who exercise special and limited 
delegations of authority.
    (c) The COCP is based on three levels of authority:
    (1) Basic. Expenditures up to and including $25,000 or the maximum 
order limitation for orders placed against established contracts.
    (2) Intermediate. Expenditures up to and including $100,000 for 
negotiation and $1,000,000 for sealed bids.
    (3) Senior. Unlimited.
[52 FR 24011, June 26, 1987, as amended at 54 FR 31964, Aug. 3, 1989]



801.690-3  Responsibility for administration of Contracting Officer Certification Program (COCP).

    (a) The Deputy Assistant Secretary for Acquisition and Materiel 
Management (A&MM). The Deputy Assistant Secretary for A&MM is 
responsible for:
    (1) Administering the COCP to ensure that the certification board 
evaluates, recommends acceptance, rejection, or termination of 
applicants at the Senior and Intermediate Levels according to the 
requirements of the COCP.
    (2) Developing additional training and the level of certification as 
required by the COCP.
    (3) Serving as the designating official, and in that capacity 
appoints or terminates contracting officers at the Senior and 
Intermediate Levels of authority.
    (b) Heads of contracting activities (HCA). The HCA is responsible 
for:
    (1) Implementing and maintaining an effective and efficient program 
for the procurement of personal property and nonpersonal services 
assigned to the activity.
    (2) Establishing adequate controls to ensure compliance with 
applicable laws and regulations.
    (3) Appointing or terminating appointments of contracting officers 
at the Basic Level within their activity. Each HCA will establish 
procedures for the appointment or termination of appointment of 
contracting officers at the Basic Level to include maintenance of 
records on individual training and experience, as well as appointment 
and termination actions.

[[Page 151]]

    (4) Recommending to the designating official the appointment or 
termination of appointment of contracting officers at the Intermediate 
and Senior Levels of authority based on candidate qualifications, as 
well as a valid organizational need.
    (c) Contracting Officer Certification Board (COCB). The COCB may 
receive, evaluate, and recommend to the designating official, candidates 
for contracting officer positions at the Intermediate and Senior Levels. 
The board will be chaired by the Deputy Director, OA&MM, and membership 
will consist of:
    (1) Director for Administration (VHS&RA) (or designee),
    (2) Deputy Director, Office of Facilities (or designee),
    (3) Acquisition Training Officer, and
    (4) Additional members to be selected on an ad hoc basis depending 
on the organizational need for certified contracting officers.
    (d) Acquisition Training Officer (ATO). The ATO in the OA&MM will 
serve as the Executive Secretary to the COCB. The ATO will coordinate 
all requests for certification with the COCB. Upon the decision by the 
Deputy Assistant Secretary for A&MM, the ATO will respond to the HCA 
with a copy of the appropriate action. In addition, the ATO will 
maintain records on the development and administration of the 
Contracting Officer Certification Program (COCP) as well as the records 
on individual training, certification and termination actions at the 
Intermediate and Senior Contracting Officer Level. The ATO will identify 
all records created and maintained and ensure they are scheduled for 
disposal by the Office of Acquisition and Materiel Management Records 
Officer.
[52 FR 24011, June 26, 1987, as amended at 54 FR 31964, Aug. 3, 1989; 54 
FR 40062, Sept. 29, 1989]



801.690-4  Selection.

    (a) Contracting officers (CO) shall be appointed only in those 
instances where a valid organizational need for certified personnel can 
be demonstrated. Such factors to be considered in making these 
assessments include complexity of work, volume of actions and 
organizational structure.
    (b) Requests for appointment of contracting officers will be made in 
writing. Request for appointments at the Senior and Intermediate Level 
will be signed by the HCA and forwarded to the Acquisition Training 
Officer (90) for processing. The request for appointment will include at 
a minimum a justification of need, and a qualification statement for the 
candidate. Requests for appointment of HCAs as contracting officers will 
be made at one level above the head of the contracting activity.
    (c) The COCB and HCAs (limited to Basic Level) will evaluate 
candidates for CO certifications based on training, experience, and 
performance, and consideration of academic education, in addition to 
meeting standards of ethical conduct and avoiding conflicts of interest. 
Minimum qualifications of contracting officers are based on a 
combination of training, experience, and performance with consideration 
of relevant academic credit or degrees earned. The following minimum 
requirements are established for designation of contracting officers:
    (1) Basic level. (i) Training--Forty hours of basic acquisition or 
small purchase training that can be accomplished on the job in 
formalized courses of instruction. If on-the-job training is conducted, 
it must be documented for the record and include a brief description of 
the duties and responsibilities that comprised that training.
    (ii) Experience--Six months of progressive work assignments and 
orientation within the last five years.
    (iii) Performance--Satisfactory rating.
    (iv) Education (desired)--High school diploma.
    (2) Intermediate level--(i) Training--(A) ATP Level I--Basic 
Acquisition.
    (B) ATP Level II--Advanced Contract Administration.
    (C) ATP Level III-- Cost and Price Analysis.

ATP courses may include tests or other assessments to indicate what 
information has been learned by the student. An assessment will then be 
made to determine if additional formal or on-the-job training is needed.

[[Page 152]]

    (ii) Experience. Two years of progressive work assignments in an 
acquisition related field leading to broader technical ability within 
the last five years.
    (iii) Performance. Satisfactory rating.
    (iv) Education (desired). Associate degree.
    (3) Senior level--(i) Training--(A) ATP Level I-- Fundamentals of 
Acquisition.
    (B) ATP Level II-- Advanced Contract Administration.
    (C) ATP Level III-- Cost and Price Analysis.
    (D) ATP Level IV-- Contract Negotiation.

ATP courses may include tests or other assessments to indicate what 
information has been learned by the student. An assessment will then be 
made to determine if additional formal or on-the-job training is needed.

    (ii) Experience. Three years of progressive assignments in an 
acquisition related field and broad technical ability within the last 
five years.
    (iii) Performance. Satisfactory rating.
    (iv) Education (desired). Bachelor degree.
    (d) Other training courses may be substituted for the prescribed 
core curriculum provided that the training meets equivalent content and 
difficulty per course. Recommending officials must fully document and 
justify equivalent courses when recommending candidates for appointment 
as contracting officers. The COCB will review and determine if 
equivalent courses may be appropriately substituted. HCAs are 
responsible for providing their subordinates with advice and assistance 
necessary to complete required training.
    (e) Candidates who achieve additional academic credit beyond the 
desired education level may be eligible to receive credit toward 
experience for this additional academic credit. Substitutions of this 
nature must be fully justified and documented by the recommending 
official and forwarded to the COCB for evaluation and appropriate 
action. Candidates will receive a maximum credit of 1 year of experience 
when substitutions are approved for the Intermediate and Senior Level. A 
maximum credit of 6 months may be approved by the HCA for the Basic 
Level.
    (f) Candidates who do not meet the minimum qualifications 
established in this section, may be granted interim appointments in 
accordance with 801.690-7.
    (g) The Privacy Act of 1974 applies to the information collected 
during the selection and appointment of contracting officers.
[52 FR 24011, June 26, 1987, as amended at 54 FR 31965, Aug. 3, 1989]



801.690-5  Appointment.

    (a) The recommending official may recommend candidates for 
appointment as contracting officers to the designating official. Only 
the Deputy Assistant Secretary for A&MM or the HCA is authorized to sign 
the Standard Form 1402, Certification of Appointment.
    (b) Specific limitations imposed upon the authority of contracting 
officer shall be set forth in certificates of appointment or otherwise 
conveyed in writing to appoint contracting officers.
    (c) Appointment of COs at specific levels does not preclude 
imposition of administrative reviews, approvals, or other limitations 
for program management purposes.
[52 FR 24012, June 26, 1987, as amended at 54 FR 31965, Aug. 3, 1989]



801.690-6  Termination.

    (a) The designating official may revoke the appointment of a 
contracting officer at any time after evaluation of written 
recommendations by an HCA or other management officials based on:
    (1) The fact that the need for the appointment no longer exists;
    (2) Personnel actions such as resignation or retirement;
    (3) Cause. (Cause covers such areas as, e.g., unsatisfactory 
performance, official misconduct pending criminal or administrative 
investigations, failure to meet training requirements.)
    (b) Situations involving termination of contracting authority of 
contracting officers for cause should be discussed with the servicing 
Personnel Office to

[[Page 153]]

determine impact, if any, on the employee's continued employment.
[54 FR 31965, Aug. 3, 1989]



801.690-7  Interim appointment provisions.

    (a) Individuals who do not meet all minimum qualifications as 
described in 801.690-4, may be appointed on an interim basis to ensure 
availability of procurement support. Requests to the designating 
official for interim appointments shall include information on the 
candidate's training, experience, performance, education, and 
justification for the interim appointment. All minimum training 
requirements shall be scheduled for individuals issued interim 
appointments and completed within a reasonable period of time. At least 
two required courses or equivalents will normally be completed each year 
after the date of appointment. Failure to complete minimum training 
requirements within the time frame may result in the loss of the interim 
appointment.
    (b) If training requirements are met during the interim appointment 
period through the ATP, a permanent warrant may be issued by the 
designating official upon satisfactory completion of all the required 
courses. Where equivalent courses have been completed, appropriate 
documentation (copies of course certificates) must be submitted before a 
permanent warrant can be issued.
    (c) Instances that may require the use of interim appointments may 
include, but are not limited to the following:
    (1) Organization changes;
    (2) Sudden extreme increases in the number of procurement requests; 
and
    (3) New hires or promotions into GS-1102 series.
    (d) Interim appointments shall normally not exceed a 2 year period.
[52 FR 24012, June 26, 1987, as amended at 54 FR 31965, Aug. 3, 1989]



801.690-8  Distribution of SF 1402, Certificate of Appointment

    (a) The original SF 1402, Certificate of Appointment, shall be 
provided to the appointed contracting officer and displayed at the 
contracting officer's duty station.
    (b) A copy of the certificate will be filed in the delegation of 
authority file and another copy will be furnished to the fiscal 
activity.
    (c) Each certificate will be serially numbered.
[54 FR 31965, Aug. 3, 1989]



801.690-9  Post appointment maintenance of certifications. [Reserved]



PART 802--DEFINITIONS OF WORDS AND TERMS--Table of Contents






                       Subpart 802.1--Definitions



802.100  Definitions

    (a) In VA, head of the contracting activity means the Director, 
Acquisition Management Service, Central Office; Deputy Assistant 
Secretary for Facilities, Central Office; Director, Building and Supply 
Service, Central Office; Director, Publications Service, Central Office; 
Director, Monument Service, Central Office; Director, Vocational 
Rehabilitation and Education Service, Central Office; Director, Loan 
Guaranty Service, Central Office; Director, VA Marketing Center; Chief, 
Supply Service, at a field facility; and the Director, Regional Office.
    (b) Procurement Executive means the Deputy Assistant Secretary for 
Acquisition and Materiel Management.
    (c) Senior Procurement Executive means the Assistant Secretary for 
Management (004). The Senior Procurement Executive is responsible for 
the management direction of the VA acquisition systems.

(38 U.S.C. 501 and 40 U.S.C. 486(c))
[52 FR 24013, June 26, 1987, as amended at 52 FR 28559, July 31, 1987; 
54 FR 40062, Sept. 29, 1989; 61 FR 1527, Jan. 22, 1996]



PART 803--IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST--Table of Contents




                        Subpart 803.1--Safeguards

Sec.
803.101  Standards of conduct.
803.101-3  Department regulations.

[[Page 154]]

      Subpart 803.2--Contractor Gratuities to Government Personnel

803.203  Reporting suspected violations of the Gratuities Clause.

        Subpart 803.3--Reports of Suspected Antitrust Violations

803.303  Reporting suspected antitrust violations.

                     Subpart 803.4--Contingent Fees

803.409  Misrepresentations or violations of the Convenant Against 
          Contingent Fees.

            Subpart 803.5--Other Improper Business Practices

803.502  Subcontractor kickbacks.

  Subpart 803.70--Contractor Responsibility To Avoid Improper Business 
                                Practices

803.7000  Policy.
803.7001  Display of VA hotline poster.
803.7002  Contract clause.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12592, Mar. 29, 1984, unless otherwise noted.



                        Subpart 803.1--Safeguards



803.101  Standards of conduct.



803.101-3  Department regulations.

    (a) Standards of conduct for all VA employees, including contracting 
officials, are found in 38 CFR part 0.
    (b) Requirements for employee financial disclosure are contained in 
38 CFR part 0, subpart D. Generally contracting officers and all 
supervisory contracting officials must file financial disclosure 
statements.
    (c) The certification in 852.203-70 will be made a part of all 
solicitations.
[49 FR 12592, Mar. 29, 1984, as amended at 61 FR 20491, May 7, 1996]



      Subpart 803.2--Contractor Gratuities to Government Personnel



803.203  Reporting suspected violations of the Gratuities Clause.

    (a) Suspected violations of the Gratuities Clause will be reported 
to the head of the contracting activity through the contracting officer. 
The head of the contracting activity will confirm that violations are 
evident and that reporting these violations to officials designated in 
paragraph (b) would be warranted.
    (b) When violations of the Gratuities Clause warrant actions 
described in FAR 3.204(c) the head of the contracting activity will 
request instructions from the VA General Counsel (025) through the 
Deputy Assistant Secretary for Acquisition and Materiel Management.
[49 FR 12592, Mar. 29, 1984, as amended at 61 FR 1527, Jan. 22, 1996]



        Subpart 803.3--Reports of Suspected Antitrust Violations



803.303  Reporting suspected antitrust violations.

    Instances of possible antitrust violations will be reported by 
procurement activities in accordance with FAR 3.303 to the Deputy 
Assistant Secretary for Acquisition and Materiel Management for review 
and submission to the General Counsel, who will determine whether or not 
to submit the case to the Attorney General.
[49 FR 12592, Mar. 29, 1984, as amended at 61 FR 1527, Jan. 22, 1996]



                     Subpart 803.4--Contingent Fees



803.409  Misrepresentations or violations of the Covenant Against Contingent Fees.

    Before taking any administrative action the heads of the contracting 
activity shall consult with their respective VA District Counsels. 
Contracting officers in Central Office shall consult with the Office of 
the General Counsel.
[49 FR 12592, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985; 61 
FR 20491, May 7, 1996]



            Subpart 803.5--Other Improper Business Practices



803.502  Subcontractor kickbacks.

    Suspected violations of the Anti-kickback Act will be reported to 
the Office of the General Counsel.

[[Page 155]]



 Subpart 803.70--Contractor Responsibililty To Avoid Improper Business 
                                Practices

    Source:  57 FR 58718, Dec. 11, 1992, unless otherwise noted.



803.7000  Policy.

    It is the Department of Veterans Affairs (VA) policy to contract 
with companies that conduct business with the highest degree of 
integrity and honesty. To demonstrate this commitment to integrity and 
honesty, contractors should have standards of conduct and internal 
control systems that are designed to promote such standards, to 
facilitate the timely discovery and disclosure of improper conduct in 
connection with Government contracts, and to assure that corrective 
measures are promptly instituted and carried out. For example, a 
contractor's system of management controls should provide for--
    (a) A written code of business ethics and standards of conduct and 
an ethics training program for all employees;
    (b) A mechanism, such as a hotline, by which employees may report 
suspected instances of improper conduct, and instructions that encourage 
employees to make such reports;
    (c) Disciplinary action for improper conduct;
    (d) Periodic reviews of company business practices, procedures, 
policies, and internal controls for compliance with standards of conduct 
and the special requirements of Government contracting;
    (e) Internal and/or external audits as appropriate;
    (f) Timely reporting to appropriate Government officials of any 
suspected or possible violations of law in connection with Government 
contracts or any other irregularities in connection with such contracts; 
and
    (g) Full cooperation with any Government agencies responsible for 
either investigation or corrective actions.



803.7001  Display of VA hotline poster.

    Contractors who are awarded a VA contract of--
    (a) $500,000 or more for supplies or services, or
    (b) $3 million or more for construction, and who have not 
established an internal reporting mechanism and program, as described in 
803.7000(b), shall be required to display prominently in common work 
areas within business segments performing work under VA contracts, the 
VA hotline poster prepared by the VA Office of Inspector General.



803.7002  Contract clause.

    The contracting officer shall insert the clause at 852.203-71, 
Display of VA hotline poster, in solicitations and contracts expected to 
equal or exceed the dollar thresholds established in 803.7001.



PART 804--ADMINISTRATIVE MATTERS--Table of Contents






                    Subpart 804.1--Contract Execution

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).



804.101  Contracting officer's signature.

    In the event a contracting officer's name and title has been typed, 
stamped or printed on the contract and the contracting officer is not 
available to sign the contract, a designee may sign for the contracting 
officer. Such designee must be a contracting officer as specified in 
801.602 and must have specific contracting authority to cover the 
contract to be signed.
[49 FR 12592, Mar. 29, 1984, as amended at 61 FR 20492, May 7, 1996]

[[Page 156]]



                   SUBCHAPTER B--ACQUISITION PLANNING





PART 805--PUBLICIZING CONTRACT ACTIONS--Table of Contents




              Subpart 805.2--Synopses of Proposed Contracts

Sec.
805.202  Exceptions.
805.205  Special situations.
805.207  Preparation and transmittal of synopses.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).



              Subpart 805.2--Synopses of Proposed Contracts



805.202  Exceptions.

    In accordance with FAR 5.202, the contract actions in 806.302-5 do 
not require synopsizing.
[51 FR 23066, June 25, 1986 and 52 FR 28559, July 31, 1987; 61 FR 20492, 
May 7, 1996]



805.205  Special situations.

    To facilitate the use of the alternative procedure in FAR 
5.205(c)(2), contracting officers are hereby delegated authority to 
procure paid advertising in a daily newspaper circulated in the local 
area, for the purpose of publicizing a proposed procurement of 
architect-engineer services expected not to exceed $10,000.
[49 FR 12592, Mar. 29, 1984]



805.207  Preparation and transmittal of synopses.

    At such time as an architect-engineer evaluation board is ready to 
advertise for architect-engineer services, it must establish the 
geographic area within which architect-engineer firms (including joint 
ventures) will be considered. The area determined must be large enough 
to assure selection of three to five firms highly qualified for the 
particular project involved, but not so large as to make the evaluation 
process unduly burdensome.
[49 FR 12592, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985; 51 
FR 23066, June 25, 1986; 52 FR 28559, July 31, 1987; 54 FR 40063, Sept. 
29, 1989; 61 FR 20492, May 7, 1996]



PART 806--COMPETITION REQUIREMENTS--Table of Contents




           Subpart 806.3--Other Than Full and Open Competition

Sec.
806.302-3  Industrial mobilization; or experimental development, or 
          research work.
806.302-5  Authorized or required by statute.
806.302-7  Public interest.
806.304  Approval of the justification.

         Subpart 806.4--Sealed Bidding and Competitive Proposals

806.401  Sealed bidding and competitive proposals.

                  Subpart 806.5--Competition Advocates

806.501  Requirement.
806.502  Duties and responsibilities.
806.570  Planning and reporting requirements.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  51 FR 23066, June 25, 1986, unless otherwise noted.



           Subpart 806.3--Other Than Full and Open Competition



806.302-3  Industrial mobilization; or experimental, development, or research work.

    Research authorized to be conducted by the Department of Veterans 
Affairs in accordance with the provisions of title 38, U.S. Code, will 
be negotiated under the authority of 41 U.S.C. 253(c)(3) (except 
prosthetics research authorized by 38 U.S.C. 4101, will be negotiated 
under the authority of 41 U.S.C. 253(c)(5), regardless of the dollar 
amount. Such acquisitions require justifications and approvals required 
by FAR 6.303 and 48 CFR 806.304.
[51 FR 23066, June 25, 1986, as amended at 61 FR 20492, May 7, 1996]



806.302-5  Authorized or required by statute.

    (a) Scarce Medical Specialist contracts negotiated under the 
authority of 38 U.S.C. 4117 are approved for other than full and open 
competition only

[[Page 157]]

when such contracts are with institutions affiliated with the Department 
of Veterans Affairs pursuant to 38 U.S.C. 4101. The justification and 
approval requirements of FAR 6.303 and 806.304 are still applicable.
    (b) Sharing contracts negotiated under 38 U.S.C. 5053 are approved 
for other than full and open competition. The justification and approval 
requirements of FAR 6.303 and 806.304 are still applicable.
    (c) Various other sections of Title 38, United States Code, 
authorize the Secretary to enter into certain contracts, and certain 
types of contracts, without regard to any other provision of law. The 
justification and approval requirements specified in FAR 6.303 and 
806.304 are still applicable. VA contracting officers entering into 
contracts using other than competitive procedures for any of the 
following items or services, estimated to cost in excess of the small 
purchase limitation, will cite, in addition to 41 U.S.C. 253(c)(5), the 
appropriate section of Title 38, United States Code, as their authority 
to do so.
    (1) Contracts for orthopedic and prosthetic appliances and related 
services including research. 38 U.S.C. 5023.
    (2) Contracts to purchase or sell merchandise, equipment, fixtures, 
supplies and services for the operation of the Veterans Canteen Service. 
38 U.S.C. 4202.
    (3) Contracts or leases for the operation of parking facilities 
established under authority of 38 U.S.C. 5009(b)(2), provides that--
    (i) The establishment, operation and maintenance of such facilities 
have been authorized by the Secretary or designee; and
    (ii) The facility director determines in writing that operation by 
contract or lease is both desirable and warranted. 38 U.S.C. 5009(b)(2).
    (4) Contracts for laundry and other common services such as the 
purchase of steam, may be noncompetitively negotiated with non-profit, 
tax-exempt, educational, medical, or community institutions, when 
specifically approved by the Secretary or designee and when such 
services are not reasonably available from private commercial sources. 
38 U.S.C. 5022(c).
    (5) Contracts or agreements with public or private agencies for 
services or translators. 38 U.S.C. 213.
    (6) Contracts for nursing home care. 38 U.S.C. 620.
[51 FR 23066, June 25, 1986, as amended at 52 FR 28560, July 31, 1987; 
54 FR 40063, Sept. 29, 1989; 61 FR 20492, May 7, 1996]



806.302-7  Public interest.

    Use of 41 U.S.C. 253(c)(7) to support contract award using other 
than full and open competition will require a D&F prepared in accordance 
with FAR subpart 1.7 and VAAR subpart 801.7 and signed by the Secretary. 
The D&F will be prepared by the contracting officer and submitted by the 
head of contracting activity (Subpart 802.1) to the Agency Competition 
Advocate (806.501). The submission will include:
    (a) The date of expected contract award (Note: Congress must be 
notified 30 days prior to award), and
    (b) A justification prepared by the contracting officer in 
accordance with FAR 6.303.
[51 FR 23066, June 25, 1986, as amended at 61 FR 20492, May 7, 1996]



806.304  Approval of the justification.

    (a) Approvals of justifications as specified in FAR 6.304, prepared 
in accordance with FAR 6.303, will be approved as follows:
    (1) For a proposed contract not exceeding $100,000, one contracting 
level above the contracting officer (see Subpart 801.6). However, if the 
contracting officer is also the head of the contracting activity 
approval will be made by:
    (i) The medical center director for acquisitions at Veterans Health 
Services and Research Administration (VHS&RA) medical centers, or
    (ii) The Agency Competition Advocate (806.501(a)) in all other 
cases.
    (2) For a proposed contract over $100,000 but not exceeding 
$1,000,000, by the Contracting Activity Competition Advocate 
(806.501(b)). However, if the Contracting Activity Competition Advocate 
is also the contracting officer, approval will be made by:
    (i) The medical center director for acquisitions at VHS&RA medical 
centers, or
    (ii) The Agency Competition Advocate in all other cases.

[[Page 158]]

    (3) For a proposed contract over $1,000,000 but not exceeding 
$10,000,000 by the Agency Competition Advocate (806.501(a)).
    (4) For a proposed contract over $10,000,000 by the Senior 
Procurement Executive (See 802.100).
    (b) Class justifications as specified in FAR 6.304(c), will be 
approved by the Agency Competition Advocate regardless of dollar amount.
[51 FR 23066, June 25, 1986, and 52 FR 28559, July 31, 1987, as amended 
at 54 FR 40063, Sept. 29, 1989; 61 FR 20492, May 7, 1996]



         Subpart 806.4--Sealed Bidding and Competitive Proposals



806.401  Sealed bidding and competitive proposals.

    Contracting officers shall solicit sealed bids if the contract is 
expected to exceed the small purchase limitation or expected to exceed 
$1,000 for contracts made for repairs to property acquired by VA under 
38 U.S.C. Chapter 37 and the criteria in FAR 6.401(a) are met. The 
contract file shall include any findings by the contracting officer that 
sealed bidding is not appropriate.
[51 FR 23066, June 25, 1986, and 52 FR 28559, July 31, 1987, as amended 
at 54 FR 40063, Sept. 29, 1989]



                  Subpart 806.5--Competition Advocates



806.501  Requirement.

    (a) The Associated Deputy Assistant Secretary for Acquisitions (90A) 
is designated as the Agency Competition Advocate.
    (b) The Director, VA Marketing Center, or designee, will serve as 
the Competition Advocate for the Center. Each head of the contracting 
activity (see Subpart 802.1) or designee will serve as the Contracting 
Activity Competition Advocate in all other cases.
[51 FR 23066, June 25, 1986, and 52 FR 28559, July 31, 1987, as amended 
at 54 FR 40063, Sept. 29, 1989; 61 FR 1527, Jan. 22, 1996]



806.502  Duties and responsibilities.

    In addition to the responsibilities identified in FAR 6.502(a), the 
Agency Competition Advocate will coordinate the competition advocacy 
program as it is implemented at all VA contracting activities. The 
Agency Competition Advocate will:
    (a) Establish program guidelines to be used by contracting activity 
competition advocates;
    (b) Assist contracting activity competition advocates with obstacles 
to promoting competition;
    (c) Utilize supply technical surveys, other facility reports, and 
the Federal Procurement Data System to monitor contracting activity 
compliance with the advocacy program;
[51 FR 23066, June 25, 1986, as amended at 61 FR 20492, May 7, 1996]



806.570  Planning and reporting requirements.

    Competition Plan. Each Contracting Activity Competition Advocate 
shall develop an initial Competition Plan for their respective 
activities by August 15, 1985. The plan should be formally incorporated 
in the internal operating procedures of the facility or organization in 
which the contracting activity is located. It is essential that the plan 
be endorsed and supported by top level management and be clearly 
understood by the services and offices that the contracting activity 
support. As a minimum, the plan shall include:
    (a) The appoval requirements for other than full and open 
competition specified in FAR 6.304;
    (b) A description of the synopsizing requirements contained in FAR 
Subpart 5.2 in order that the necessity for Advance Procurement Planning 
is fully understood;
    (c) A description of how the Competition Plan should be integrated 
into Advance Procurement Planning;
    (d) Identification of any known obstacles to competition and a 
proposal for overcoming them;
    (e) A method for otherwise increasing competition for contracts on 
the basis of cost and other significant factors.
[51 FR 23066, June 25, 1986, as amended at 61 FR 20492, May 7, 1996]

[[Page 159]]



PART 807--ACQUISITION PLANNING--Table of Contents




         Subpart 807.3--Contractor Versus Government Performance

Sec.
807.300  Scope of subpart.
807.304  Procedures.
807.304-73  Bid opening/receipt of proposals.
807.304-75  Bid acceptance.
807.304-76  Contract effective date.
807.304-77  Right of first refusal.

    Authority:  38 U.S.C. 501; 40 U.S.C. 486(c).

    Source:  53 FR 43210, Oct. 26, 1988, unless otherwise noted.



         Subpart 807.3--Contractor Versus Government Performance



807.300  Scope of subpart.

    This subpart prescribes basic procedures and principles to be 
followed in performing the contracting aspect of the OMB Circular A-76 
cost comparison process.



807.304  Procedures.



807.304-73  Bid opening/receipt of proposals.

    The date established for bid opening or receipt of proposals will 
normally be 90 days after sending the request for publication to the 
Commerce Business Daily (CBD) (65 days after issuing the solicitation).



807.304-75  Bid acceptance.

    Bid acceptance shall be 90 days from bid opening/receipt of 
proposals in order to accommodate the time necessary to evaluate bids/
offers, finalize the cost comparison and process any appeals. 
Contracting officers will insert ``90 days'' in FAR clause 52.214-15.



807.304-76  Contract effective date.

    (a) A transition from in-house performance to contract requires a 
period of time from contract award to beginning of contract performance 
(contract effective date). This time is necessary to allow for personnel 
adjustments, e.g., right of first refusal process, and to allow a 
reasonable period for the contractor to make necessary resource 
reallocations. The contract effective date should be carefully 
considered in conjunction with the A-76 Task Group and must be specified 
in the solicitation.
    (b) Although outplacement planning to minimize the effect of any 
necessary reduction in force should be initiated in advace of bid 
opening/receipt of proposals as prescribed by Office of Personnel and 
Labor Relations, there are also employee and labor organization 
reduction-in-force notice requirements which must be satisfied.
    (c) When bargaining unit employees will be affected, facility 
officials also should review and comply with any employee or labor 
organization notice requirements in applicable negotiated agreements.



807.304-77  Right of first refusal.

    (a) In addition to the Right of First Refusal clause specified in 
FAR 52.207-3, the contracting officer will include the clause ``Report 
of Employment Under Commercial Activities'' in 852.207-70. This clause 
is primarily intended to verify that the contractor is meeting its 
obligation to provide adversely affected Federal workers the first 
opportunity for employment openings, for which they qualify, created by 
the contract.
    (b) The Report of Employment Under Commercial Activities clause is 
also prescribed to avoid inappropriate severance payment. In order to 
implement the clause, the contracting officer (or Contracting Officer's 
Technical Representative (COTR)) must first obtain a list from the 
servicing personnel office of Federal employees, including their Social 
Security numbers, who will be adversely affected as a result of the 
anticipated contract. The list should be requested as soon as a 
preliminary determination is made to contract out a function subject to 
A-76. (Contracting officers may designate a COTR to coordinate the 
information and reporting requirements.)



PART 808--REQUIRED SOURCES OF SUPPLIES AND SERVICES--Table of Contents




Sec.
808.001  Priorities for use of Government supply sources.

[[Page 160]]

          Supbart 808.4--Ordering From Federal Supply Schedules

808.401  General.
808.404-1  Mandatory use.
808.404-3  Requests for waivers.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12593, Mar. 29, 1984, unless otherwise noted.



808.001  Priorities for use of Government supply sources.

    (a) Procurement will be effected from the following sources in the 
descending order of priority as indicated herein:
    (1) VA excess.
    (2) Other government agencies excess.
    (3) Federal Prison Industries.
    (4) Procurement list of products available from the Committee for 
Purchase from the Blind and Other Severely Handicapped.
    (5) GSA stock and other Government agency inventory.
    (6) VA decentralized contracts.
    (7) Mandatory Federal Supply Schedule contracts.
    (8) Optional use Federal Supply Schedule contracts.
    (9) Commercial concerns, educational, or nonprofit institutions, as 
applicable.
    (b) Public exigency. A source lower in priority may be utilized in a 
public exigency as defined in FAR 6.302-2 and in Federal Property 
Management Regulation 41 CFR 101-25.101-5. Justification for each 
deviation must be included in the procurement file.
    (c) Eligible Beneficiaries. When it is determined that a therapeutic 
benefit to eligible beneficiaries will result from personal selection of 
shoes, clothing and incidentals, acquisition from the Veterans Canteen 
Service or commercial sources is authorized. When dress shoes similar to 
Federal Prison Industries, Inc., Style No. 86-A are purchased from 
commercial sources, FPI clearance No. 1206 will be cited on the purchase 
document.
[49 FR 12593, Mar. 29, 1984, as amended at 51 FR 23068, June 25, 1986; 
52 FR 28559, July 31, 1987; 54 FR 40063, Sept. 29, 1989; 61 FR 20492, 
May 7, 1996]



          Subpart 808.4--Ordering From Federal Supply Schedules



808.401  General.

    The Director, VA Marketing Center, advertises, negotiates, awards 
the contracts, and is responsible for contract administration for FSS 
(Federal Supply Schedule) Groups 65 and 89. The Director issues the 
Federal Supply Schedules containing the necessary information for 
placing delivery orders with the contractors for the above FSS Groups.



808.404-1  Mandatory use.

    (a) The contracting officer shall submit a request to the Director, 
VA Marketing Center, to negotiate a separate contract when requirements 
will exceed the maximum order limitation cited in the contract.
    (b) Lower prices for identical items. (1) When an ordering agency 
finds an item which is identical to one listed on FSS Group 65 or 89, 
but available at a lower delivered price from a lower priority source, 
the ordering office may purchase the item subject to the requirements 
set forth in FAR 8.404-1(e). A copy of the purchase order shall be sent 
to the Director, VA Marketing Center, at the time the order is issued.
    (2) An identical item is defined as: (i) nondrug item--same 
manufacturer and model number, or (ii) drug item--have the same National 
Drug Code (NDC) number.
[49 FR 12593, Mar. 29, 1984, as amended at 51 FR 19350, May 29, 1986; 54 
FR 40063, Sept. 29, 1989]



808.404-3  Requests for waivers.

    When an ordering office determines that an item available from FSS 
Group 65 or 89 will not meet its specific needs, it should submit a 
request for waiver to the Director, VA Marketing Center. The request 
shall contain the information set forth in FAR 8.404-3(a)(1) through 
(4).
[51 FR 19350, May 29, 1986]

[[Page 161]]



PART 809--CONTRACTOR QUALIFICATIONS--Table of Contents




           Subpart 809.1--Responsible Prospective Contractors

Sec.
809.104-2  Special standards.
809.106-1  Conditions for preaward surveys.

                    Subpart 809.2--Qualified Products

809.206  Acquiring qualified products.
809.270  Qualified products for convenience/labor saving foods.

         Subpart 809.4--Debarment, Suspension, and Ineligibility

809.400  Scope of subpart.
809.403  Definitions.
809.404  Consolidated list of debarred, suspended, and ineligible 
          contractors.
809.405  Effect of listing.
809.406  Debarment.
809.406-1  General.
809.406-3  Procedures.
809.406-4  Period of debarment.
809.407  Suspension.
809.407-1  General.
809.407-3  Procedures.

           Subpart 809-5--Organizational Conflicts of Interest

809.504  Contracting officer's responsibilities.
809.505  General rules.
809.508-2  Contract clause.

  Subpart 809.7--Defense Production Pools and Research and Development 
                                  Pools

809.702  Contracting with pools.

    Authority:  38 U.S.C. 210, 40 U.S.C. 486(c) and 42 U.S.C. 2453(c).

    Source:  49 FR 12594, Mar. 29, 1984, unless otherwise noted.



           Subpart 809.1--Responsible Prospective Contractors



809.104-2  Special standards.

    Standards applicable to subsistence will be established based on 
preaward surveys prescribed by 809.106-1.



809.106-1  Conditions for preaward surveys.

    (a) Preaward on-site evaluation will be made for contracts covering 
the products and services of bakeries, dairies, ice cream plants and 
laundry and dry cleaning activities. A committee under the direction of 
the contracting officer and composed of representatives of the medical 
service and/or using service chiefs or designees appointed by the 
facility director will inspect and evaluate the plant, personnel, 
equipment and processes of the prospective contractor. Prior to any 
inspection, the contracting officer will inquire whether the plant has 
been recently inspected and approved by another Department of Veterans 
Affairs facility or Federal agency. Approved inspection reports of 
another Department of Veterans Affairs facility will be accepted by 
Department of Veterans Affairs facilities and approved inspection 
reports of other Federal agencies may be accepted as satisfactory 
evidence that the facilities of the bidder meet the requirements of the 
Invitation for Bid, provided inspection was made not more than 6 months 
prior to the proposed contract period.
    (b) Preaward on-site evaluation of dairy plants will not be made by 
the Department of Veterans Affairs when acceptable bids are received 
from suppliers of those dairy products designated as No. 1 in the 
Federal Specifications. Suppliers must have received, prior to opening 
of bids, a pasteurized milk rating of 90 percent or more for the type of 
product being supplied, on the basis of the U.S. Public Health Service 
milk ordinance and code. Such rating must be current (not over 2 years 
old), and will have been determined by certified State milk sanitation 
rating officer in the State of origin or by the Public Health Service 
and will continue at 90 percent or more during the period of the 
contract. Firms not so rated may only offer dairy products designated as 
No. 2 in the Federal Specifications. Award to such firms may be made 
only after completion of a preaward on-site evaluation conducted in 
accordance with paragraph (a) of this section.
    (c) Prior to any open market purchase of fresh bakery products (such 
as pies, cakes, cookies), the plant where these products are produced or 
prepared will be inspected and evaluated as provided in paragraph (a) of 
this section. On-site evaluation will be made at least annually and 
recorded on VA

[[Page 162]]

Form 10-2079, Inspection Report of Bakery.
[49 FR 12594, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989; 
54 FR 40063, Sept. 29, 1989]



                    Subpart 809.2--Qualified Products



809.206  Acquiring qualified products.

    (a) Federal Qualified Products Lists are lists of products qualified 
under the applicable Federal or interim Federal specification. Such 
lists may be used as authorized by the appropriate administration or 
staff office. Requests to receive copies of existing Federal Qualified 
Products Lists will be submitted to the Deputy Assistant Secretary for 
Acquisition and Materiel Management (91) for transmittal to General 
Services Administration. Requests to establish a Federal Qualified 
Products List for a commodity will be submitted to the Deputy Assistant 
Secretary for Acquisition and Materiel Management (91), supported by one 
or more of the following justifications:
    (1) The time required for testing after award would unduly delay 
delivery of the supplies being purchased.
    (2) The cost of repetitive testing would be excessive.
    (3) The tests would require expensive or complicated testing 
apparatus not commonly available.
    (4) The interest of the Government requires assurance, prior to 
award, that the product is satisfactory for its intended use.
    (5) The determination of acceptability would require performance 
data to supplement technical requirements in the specification.
    (b) VA Qualified Products Lists are lists of products qualified by 
VA under VA specifications or purchase descriptions. Such lists may be 
established as authorized by the appropriate administration or staff 
office.
    (1) VA Qualified Products Lists will be supported by one or more of 
the justifications in 809.206(a) or the following:
    (i) Where tests result in substantial or repetitive rejections, or
    (ii) Where professional requirements of performance, balance, 
design, or construction cannot economically be developed into clear 
specifications, and professional judgment is required in determining the 
acceptability of items meeting VA requirements.
    (2) In the event that the requirement for VA Qualified Products List 
is established for any given product, known suppliers of the type of 
item required will be notified and given an opportunity to submit 
samples for inspection, and test based upon guarantee that they will 
deliver the item to be inspected, provided the item is acceptable. A 
qualified products list shall not be used as a means of restricting 
competition to favored suppliers. All suppliers so desiring shall be 
given an opportunity to have their products tested for acceptability.
    (3) Costs involved in the inspection and test will be borne by VA. 
The supplier will be required to bear the cost of the sample and its 
transportation to the inspecting point. After inspection, the sample 
shall be returned to the supplier ``as is'' unless it is destroyed by 
inspection or disposed of or retained by VA as authorized by the 
supplier.
    (4) Items which have been accepted for the qualified products list 
will be subject to constant review for compliance with the applicable 
specification. Where there is a variance between the specification and 
item, the supplier shall be requested to furnish an item that conforms 
to the specification. Failure or inability on the part of the supplier 
to provide an item that conforms to the specification will be sufficient 
cause to consider the item unacceptable in response to subsequent 
invitations.
    (5) The acceptance of an item for the qualified products list does 
not guarantee acceptance in any future purchase, nor does it constitute 
a waiver of the requirements of the specifications as to acceptance, 
inspection, testing or other provisions of any future contract involving 
such item.
    (6) Bid invitations covering products which have been included in a 
qualified products list will include the clause set forth in FAR 52.209-
1 or 52.209-2 as applicable.
[49 FR 12594, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989; 
54 FR 40063, Sept. 29, 1989]

[[Page 163]]



809.270  Qualified products for convenience/labor saving foods.

    (a) Each VA medical district's Dietetic Service representative is 
delegated authority to establish a common Qualified Products List for 
convenience/labor-saving foods for the use of medical centers within 
his/her respective district. The medical district Dietetic Service 
representative will notify the Director, Dietetic Service, VA Central 
Office, of the establishment of each Qualified Products List and 
amendments to each established list.
    (b) Each medical center is authorized to use its district Qualified 
Products List. Each medical center may test food of its own choice, but 
will submit test results to the district Dietetic Service 
representative. The Dietetic Service representative will coordinate and 
consolidate the test results and recommendations of individual medical 
centers with other medical centers within the district in order to avoid 
unnecessary duplication.
    (c) The approved medical district Qualified Products List will be 
furnished each Supply office within the district. The Supply Services 
will have access to complete and accurate records of established 
Qualified Products Lists and all test results. These records will be 
made available to the Office of Acquisition and Materiel Management, VA 
Central Office, upon request.
[49 FR 12594, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989]



         Subpart 809.4--Debarment, Suspension, and Ineligibility



809.400  Scope of subpart.

    This subpart prescribes procedures for debarring or suspending 
contractors and the inclusion of those contractors on the consolidated 
list of debarred, suspended or ineligible bidders.



809.403  Definitions.

    Fact-finding as used in this subpart shall mean a gathering of facts 
which is accomplished through informal meetings with the contractor, 
submissions of information, either verbally or in writing, by the 
contractor, and any other method deemed appropriate by the debarring 
official.
[49 FR 12594, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985]



809.404  Consolidated list of debarred, suspended, and ineligible contractors.

    (a) The Office of Acquisition and Materiel Management (93) shall be 
responsible for the action described in FAR 9.404(c) (1), (2), (4) and 
(6).
    (b) The Office of Acquisition and Materiel Management (91) shall be 
responsible for the actions described by FAR 9.404(c) (3) and (5).
[49 FR 12594, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989]



809.405  Effect of listing.

    The Deputy Assistant Secretary for Acquisition and Materiel 
Management shall make the determinations required by FAR 9.405(a) and 
9.405-2 to solicit from, award contracts to, or consent to subcontracts 
with contractors whose names are included on the consolidated list of 
debarred, suspended or ineligible contractors.
[49 FR 12594, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989]



809.406  Debarment.



809.406-1  General.

    (a) The Deputy Assistant Secretary for Acquisition and Materiel 
Management is the debarring official for the Department of Veterans 
Affairs.
    (b) Any Department of Veterans Affairs employee may submit a 
recommendation to the Deputy Assistant Secretary for Acquisition and 
Materiel Management that a firm or individual be debarred by the 
Department of Veterans Affairs.
    (c) Such recommendations must be supported by documentary evidence 
of a cause listed in FAR 9.406-2.



809.406-3  Procedures.

    (a) The Deputy Assistant Secretary for Acquisition and Materiel 
Management shall, upon a receipt of a recommendation for debarment, 
appoint a designee to conduct an investigation, initiate debarment and 
present the

[[Page 164]]

facts to the debarring official for consideration and action.
    (b) The appointed designee shall issue the proposed debarment notice 
as required by FAR 9.406-3(c).
    (1) If no reply is received from the firm or individual to the 
notice of proposed debarment, the case will be referred to the debarring 
official for decision on the basis of information available.
    (2) When a reply is received, the information provided will be 
considered by the appointed designee prior to making a recommendation to 
the debarring official. If the contractor's submission in opposition to 
the debarment raises a genuine dispute over facts material to the 
proposed debarment, the designee appointed by the Deputy Assistant 
Secretary for Acquisition and Materiel Management will conduct a fact-
finding as prescribed by FAR 9.406-3(b)(2).
    (3) Upon completion of the fact-finding with respect to disputed 
facts, a written findings of facts will be provided to the debarring 
official.
    (4) The debarring official shall make a decision on the basis of all 
information available including findings of facts, and/or arguments 
submitted by the contractor.
[49 FR 12594, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985]



809.406-4  Period of debarment.

    The period of debarment will be based upon the circumstances 
involved but will not, except in unusual circumstances, exceed a period 
of 3 years. The Deputy Assistant Secretary for Acquisition and Materiel 
Management may for those firms or individuals debarred by the Department 
of Veterans Affairs decide to remove the debarment, reduce the period of 
debarment, or amend the scope of the debarment, if indicated, after 
review of documentary evidence submitted by or in behalf of the 
contractor setting forth the appropriate grounds for granting of such 
relief. Such grounds may be, but are not limited to, newly discovered 
material evidence, reversal of a conviction, bona fide change of 
ownership or management or the elimination of the cause for which 
debarment was imposed.



809.407  Suspension.



809.407-1  General.

    The Deputy Assistant Secretary for Acquisition and Materiel 
Management is the suspending official for the Department of Veterans 
Affairs.



809.407-3  Procedures.

    (a) Suspension may be recommended by any Department of Veterans 
Affairs employee. These recommendations will be submitted to the Deputy 
Assistant Secretary for Acquisition and Materiel Management and must be 
supported by documentary evidence of a cause listed in FAR 9.407-2.
    (b) The Deputy Assistant Secretary for Acquisition and Materiel 
Management shall designate an official to initiate suspension, conduct 
an investigation and present the facts to the suspending official for 
consideration and appropriate action.
    (c) The designee shall issue the proposed suspension notice as 
required by FAR 9.407-3(c).
    (1) If no reply is received from the contractor to the notice of 
proposed suspension, the case will be referred to the suspending 
official for decision on the basis of information available.
    (2) When a reply is received, the information provided will be 
considered by the official conducting the suspension proceedings prior 
to referring the case with recommendations to the suspending official. 
If the contractor's submission in opposition to the suspension raises a 
genuine dispute over facts material to the proposed suspension, the 
designee of the Deputy Assistant Secretary for Acquisition and Materiel 
Management will conduct a fact-finding as prescribed by FAR 9.407-
3(b)(2).
    (3) Upon completion of the informal hearing with respect to the 
disputed facts, a written findings of facts will be prepared and 
presented to the suspending official.
    (4) The suspending official shall make a decision on the basis of 
all information available including findings of facts, and/or arguments 
submitted by the contractor.

[[Page 165]]



           Subpart 809.5--Organizational Conflicts of Interest



809.504  Contracting officer's responsibilities.

    (a) Contracting officers will be responsible for determining the 
existence of actual and/or potential organizational conflicts of 
interest which would result from the award of the contract. The 
contracting officer will be guided by information submitted by offerors 
and by his/her own judgment. The contracting officer may obtain the 
advice of legal counsel and the assistance of technical specialists in 
evaluating potential organizational conflicts.
    (b) If it is determined that organizational conflicts of interest 
will be created by the award of the contract, the contracting officer 
may find an offeror nonresponsible.
    (c) Notwithstanding the existence of organizational conflicts of 
interest, it may be determined that the award of the contract would be 
in the best interest of the Government. In that case, the contracting 
officer may set terms and conditions which will reduce the 
organizational conflicts of interest to the greatest extent possible, 
with the approval of the head of the contracting activity.
    (d) The contracting officer will, in addition to any certifications 
required by this subpart, require in all solicitations for consulting 
services that the offeror submit as part of an offer a statement which 
discloses all relevant facts relating to existing or potential 
organizational conflicts of interest surrounding the contract and/or the 
proposed use of subcontractors during the contract.



809.505  General rules.

    The determination that organizational conflicts of interest exist 
can only be made when facts surrounding individual contracting 
situations are known. Therefore, it is up to the contracting officer to 
exercise common sense, good judgment and sound discretion in making such 
a determination and to take steps to mitigate to the greatest extent 
possible organizational conflicts of interest. The contracting officer 
will be guided by at least two underlying principles. These are that 
organizational conflicts of interest may result from (a) conflicting 
roles and interests of the contractor, in which case he/she would be 
unable to give unbiased and objective advice or may otherwise produce a 
biased work product; or (b) unfair competitive advantage which exceeds a 
normal flow of benefits from the award of the contract.



809.508-2  Contract clause.

    The representation in 852.209-70, Organizational Conflicts of 
Interest, will be made a part of all solicitations for consulting 
services.
[49 FR 12594, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985]



  Subpart 809.7--Defense Production Pools and Research and Development 
                                  Pools



809.702  Contracting with pools.

    Department of Veterans Affairs contracting officers will be advised 
of, consider bids from, and make awards to, Small Business and Defense 
Production Pools. The Chief Medical Director, or designee, will notify 
the appropriate administrations and staff offices when such pools are 
approved.
[49 FR 12594, Mar. 29, 1984, as amended at 54 FR 40063, Sept. 29, 1989]



PART 810--SPECIFICATIONS, STANDARDS AND PURCHASE ORDER DESCRIPTIONS--Table of Contents




Sec.
810.001  Definitions.
810.004  Selecting specifications or descriptions for use.
810.004-70  Sealed bidding.
810.004-71  Bid evaluation and award.
810.004-72  Procedure for negotiated procurements.
810.006  Using specifications and standards.
810.007  Deviations.
810.011  Solicitation provisions and contract clauses.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  52 FR 281, Jan. 5, 1987, unless otherwise noted.

[[Page 166]]



810.001  Definitions.

    (a) Brand name product means a commercial product described by brand 
name and make or model number or other appropriate nomenclature by which 
such product is offered for sale to the public by the particular 
manufacturer, producer or distributor.
    (b) Salient characteristics are those particular characteristics 
that specifically describe the essential physical and functional 
features of the material or service required. They are those essential 
physical or functional features which are identified in the 
specifications as a mandatory requirement which a proposed ``equal'' 
product or material must possess in order for the bid to be considered 
responsive. Bidders must furnish all descriptive literature and bid 
samples required by the solicitation to establish such ``equality''.



810.004  Selecting specifications or descriptions for use.

    (a) Specifications shall be written in accordance with FAR 10.002 
unless otherwise justified by the specification writer and approved by 
the contracting officer as described in paragraph (b) of this section. 
The contract file shall be documented accordingly.
    (b) When it is determined that a particular physical or functional 
characteristic of only one product will meet the minimum requirements of 
the Department of Veterans Affairs (see FAR 10.004(b)(2)) or that a 
``brand name or equal'' purchase description will be used (see FAR 
10.004(b)(3)), the specification writer, whether agency personnel, 
architect-engineer, or consultant with which the Department of Veterans 
Affairs has contracted, shall separately identify the item(s) to the 
contracting officer and provide a full written justification of the 
reason the particular characteristic is essential to the Government's 
requirements or why the ``brand name or equal'' purchase description is 
necessary. The contracting officer shall make the final determination 
whether specifications in FAR 10.004(b) (2) and (3), will be included in 
the solicitation.
    (c) Purchase descriptions which contain references to one or more 
brand name products may be used only when authorized by FAR 10.004(b) 
and 10.006(a) and in accordance with 810.004-70, 810.004-71, and 
810.004-72. In addition, purchase descriptions which contain references 
to one or more brand name products shall be followed by the words ``or 
equal,'' except when the acquisition is fully justified under FAR 6.3 
and VAAR 806.3. Acceptable brand name products should be listed in the 
solicitation. Where a ``brand name or equal'' purchase description is 
used, prospective contractors must be given the opportunity to offer 
products other than those specifically referenced by brand name if such 
other products are determined by the Government to fully meet the 
salient characteristics listed in the invitation. The contract file will 
be documented in accordance with paragraph (b) of this section, 
justifying the need for use of a brand name or equal description.
    (d) ``Brand name or equal'' purchase descriptions shall set forth 
those salient physical, functional, or other characteristics of the 
referenced products which are essential to the minimum needs of the 
Government. For example, when interchangeability of parts is required, 
such requirement should be specified. Purchase descriptions shall 
contain the following information to the extent available, and include 
such other information as is necessary to describe the item required:
    (1) Complete common generic identification of the item required;
    (2) Applicable model, make or catalog number for each brand name 
product referenced, and identity of the commerical catalog in which is 
appears; and
    (3) Name of manufacturer, producer or distributor of each brand name 
product referenced (and address if not well known).
    (e) When necessary to describe adequately the item required, an 
applicable commercial catalog description or pertinent extract may be 
used if such description is identified in the solicitation as being that 
of the particular named manufacturer, producer or distributor. The 
contracting officer will insure that a copy of any catalogs referenced 
(except parts catalogs) is available on request for review by bidders at 
the purchasing office.

[[Page 167]]

    (f) Except as noted in paragraph (c) of this section, purchase 
descriptions shall not include either minimum or maximum restrictive 
dimensions, weights, materials or other salient characteristics which 
are unique to a brand name product or which would tend to eliminate 
competition or other products which are only marginally outside the 
restrictions, unless such restrictions are determined in writing by the 
user to be essential to the Government's requirements, the brand name of 
the product is included in the purchase description and all other 
determinations required by 810.004 have been made.



810.004-70  Sealed bidding.

    (a) When any purchase description, including a ``brand name or 
equal'' purchase description, is used in a solicitation for a supply 
contract to describe required items of mechanical equipment, the 
solicitation will include the clauses in 852.210-70 (Service Data 
Manual) and in 852.210-71 (Guarantee).
    (b) Solicitations using ``brand name or equal'' purchase 
descriptions will contain the ``brand name or equal'' provision in 
852.210-77, and the provision set forth at FAR 52.214-21, Descriptive 
Literature. Contracting officers are cautioned to review the 
requirements at FAR 14.202-5(d) when utilizing the descriptive 
literature provision.
    (c) Except as provided in 810.004-70(d), when a ``brand name or 
equal'' purchase description is included in an invitation for bids, the 
following shall be inserted after each item so described in the 
solicitation, for completion by the bidder:
    Bidding on:

 Manufacturer name______________________________________________________

 Brand__________________________________________________________________

 No.____________________________________________________________________

    (d) When component parts of an end item are described in the 
solicitation by a ``brand name or equal'' purchase description and the 
contracting officer determines that the clause in 810.004-70(b) is 
inapplicable to such component parts, the requirements of 810.004-70(c) 
shall not apply with respect to such component parts. In such cases, if 
the clause is included in the solicitation for other reasons, a 
statement substantially as follows also shall be included:

    The clause entitled ``Brand Name or Equal'' does not apply to the 
following component parts: (list the component parts to which the clause 
does not apply).


In the alternative, if the contracting officer determines that the 
clause in 810.004-70(c) shall apply to only certain such component 
parts, the requirements of 810.004-70(b) shall apply to such component 
parts and a statement substantially as follows also shall be included:

    The clause entitled ``Brand Name or Equal'' applies to the following 
component parts: (list the component parts to which the clause applies).

    (e) When a solicitation contains ``brand name or equal'' purchase 
descriptions, bidders who offer brand name products, including component 
parts, referenced in such descriptions shall not be required to furnish 
bid samples of the referenced brand name products. However, 
solicitations may require the submission of bid samples in the case of 
bidders offering ``or equal'' products. If bid samples are required, the 
solicitation shall include the provision set forth at FAR 52.214-20, Bid 
Samples. The bidder must still furnish all descriptive literature in 
accordance with and for the purpose set forth in the ``Brand Name of 
Equal'' clause, 852.210-77(c)(1) and (2), even though bid samples may 
not be required.
[52 FR 281, Jan. 5, 1987, as amended at 53 FR 7755, Mar. 10, 1988]



810.004-71  Bid evaluation and award.

    (a) Bids offering products which differ from brand name products 
referenced in a ``brand name or equal'' purchase description shall be 
considered for award when the contracting officer determines in 
accordance with the terms of the clause at 852.210-77 that the offered 
products are clearly identified in the bids and are equal in all 
material respects to the products specified.
    (b) Award documents shall identify, or incorporate by reference, an 
identification of the specific products which the contractor is to 
furnish. Such identification shall include any brand name

[[Page 168]]

and make or model number, descriptive material, and any modifications of 
brand name products specified in the bid. Included in this requirement 
are those instances when the descriptions of the end items contain 
``brand name or equal'' purchase descriptions of component parts or of 
accessories related to the end item, and the clause at 852.210-77 was 
applicable to such component parts or accessories (see 810.004-70(e)).



810.004-72  Procedure for negotiated procurements.

    (a) The policies and procedures prescribed in 810.004-70 and 
810.004-71 should be used as a guide in developing adequate purchase 
descriptions for negotiated procurements.
    (b) The clause at 852.210-77 may be adapted for use in negotiated 
procurements. If use of the clause is not practicable (as may be the 
case in unusual and compelling urgency purchases), suppliers shall be 
suitably informed that proposals offering products different from the 
products referenced by brand name will be considered if the contracting 
officer determines that such offered products are equal in all material 
respects to the products referenced.



810.006  Using specifications and standards.

    (a) Exceptions to mandatory use of Federal specifications. The 
exception to the mandatory use of Federal specifications, with respect 
to purchases not exceeding the small purchase limitation authorized by 
FAR 10.006(a)(ii) does not apply to items (1) purchased from GSA stock, 
(2) available from a Federal supply schedule contract, or (3) identified 
by a VA X-Series Specification.
    (b) Optional use of interim Federal specifications. (1) Interim 
Federal specifications, developed by VA, as indicated in the preamble, 
are mandatory under the same conditions and with the same exceptions as 
provided for Federal specifications.
    (2) Suggested changes to interim Federal specifications used on an 
optional basis will be handled as in 810.007.
    (c) Military and departmental specifications. (1) The monetary 
exemption to the use of Federal specifications contained in FAR 
10.006(a)(ii) is equally applicable to Department of Veterans Affairs, 
military and departmental specifications. Contracting officers may, when 
they deem it to be advantageous to the Department of Veterans Affairs, 
utilize these specifications when procuring supplies and equipment 
costing less than the small purchase limitation. However, when 
purchasing items of perishable subsistence, contracting officers shall 
observe only those exemptions set forth in paragraphs (c) (5) and (6) of 
this section.
    (2) When circumstances will not permit a field station to use a 
Department of Veterans Affairs specification without deviation, the 
contracting officer shall, prior to taking any procurement action, 
submit to the Deputy Assistant Secretary for Acquisition and Materiel 
Management, or Director, VA Marketing Center, Hines, Ill., whichever is 
appropriate, a request for authority to deviate from the specification. 
The request will specifically detail the reasons why the deviation is 
essential to the facility's operation. The approving authority will 
coordinate the request with the using service in Central Office. The 
contracting officer will be advised as to the approval or disapproval of 
the request. If approved the letter of approval will be filed in the 
appropriate purchase or contract file.
    (3) The Department of Veterans Affairs has adopted for use in the 
procurement of packinghouse products, the purchase descriptions and 
specifications set forth in the Institutional Meat Purchase 
Specifications (IMPS), and the IMPS General Requirements, which have 
been developed by the U.S. Department of Agriculture. Purchase 
descriptions and specifications for dairy products, poultry, eggs, fresh 
and frozen fruits and vegetables, as well as certain packinghouse 
products selected from the IMPS especially for Department of Veterans 
Affairs use, are contained in the Federal Hospital Subsistence Guide. A 
copy of this guide and the IMPS may be obtained from any Department of 
Veterans Affairs contracting officer.
    (4) Contract terms and conditions governing the procurement of 
subsistence items are listed in the Federal Hospital Subsistence Guide 
and IMPS.

[[Page 169]]

These provisions shall be made a part of each solicitation for such 
items when applicable.
    (5) The military specifications for meat and meat products contained 
in Federal Hospital Subsistence Guide shall be used by the Department of 
Veterans Affairs only when purchasing such items of subsistence from the 
Defense Logistics Agency (DLA). Military specifications for poultry, 
eggs, and egg products contained in Federal Hospital Subsistence Guide 
may be used when purchasing either from DLA or from local dealers.
    (6) Except as authorized in part 846 of this chapter, contracting 
officers shall not deviate from the specifications contained in Federal 
Hospital Subsistence Guide, and the IMPS without prior approval of the 
Deputy Assistant Secretary for Acquisition and Materiel Management.
    (7) Items of meat, cured pork and poultry, not listed in either the 
Federal Hospital Subsistence Guide or the IMPS, will not be purchased 
without prior approval of the Deputy Assistant Secretary for Acquisition 
and Materiel Management.
    (8) In the absence of mandatory documents, specifications or 
purchase descriptions of other agencies may be used by the various 
Marketing Divisions when appropriate. These specifications or purchase 
descriptions may be modified to meet the needs of the Department of 
Veterans Affairs. If repeated use of a modified specification or 
purchase description is required, the Director, VA Marketing Center 
shall consider converting it to a Department of Veterans Affairs 
specification.
    (9) A field facility may use a specification or purchase description 
of another agency without prior approval when the specification or 
description will, without modification, satisfy its needs. If, however, 
the specification or description must be modified to meet the facility's 
needs, the procedure set forth in paragraph (c)(2) of this section will 
be followed.
    (10) The Director, Publications Service, is responsible for 
developing, publishing, and distributing Department of Veterans Affairs 
specifications covering printing and binding.
    (11) Department of Veterans Affairs specifications, as they are 
revised, are placed in stock in the VA Forms and Publications Depot. 
Facility requirements of these specifications will be requisitioned from 
that source.
    (d) Government paper specification standards. Invitations for bids, 
requests for proposals, purchase orders, or other procurement 
instruments covering the purchase of paper stocks to be used in 
duplicating or printing, or which specify the paper stocks to be used in 
buying printing, binding, or duplicating will require that such paper 
stocks be in accordance with the government Paper Specification 
Standards issued by the Joint Committee on Printing of Congress.
    (e) Department of Veterans Affairs binding specifications. (1) All 
binding or rebinding of books, magazines, pamphlets, newspapers, slip 
cases and boxes will be procured in accordance with Government Printing 
Office (GPO) specifications and will be procured from the servicing GPO 
Regional Printing Procurement Office or, when appropriate, from 
commercial sources as prescribed in Subpart 808.8.
    (2) There are three types of binding/rebinding: (i) Class A (hard 
cover); (ii) Perfect (glued); and (iii) Lumbinding (sewn). The most 
suitable type of binding will be procured to satisfy the requirements, 
based upon the intended use of the bound material.
    (f) Mandatory use and applications of Federal standards. (1) 
Requests for exceptions to Federal Standards not authorized by FAR 
10.006(a)(ii) will be submitted with adequate justification to the 
Deputy Assistant Secretary for Acquisition and Materiel Management (91A) 
for submission to General Services Administration.
    (2) Federal standards do not preclude the use of existing Government 
stocks or acceptance of excess property not in full conformity with the 
standard items.
[49 FR 12597, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985; 54 
FR 30044, July 18, 1989; 54 FR 40063, Sept. 29, 1989]



810.007  Deviations.

    (a) Deviations from Federal specifications--(1) Field facility. When 
a deviation from a Federal specification is

[[Page 170]]

deemed necessary because of a specific requirement, the contracting 
officer will request such authority from the Deputy Assistant Secretary 
for Acquisition and Materiel Management, prior to procurement. The 
request will specify exactly how the facility proposes to deviate from 
the current specification and why the particular deviation is essential 
to the facility's operations. The contracting officer will be advised as 
to approval or disapproval of the request. If approved, the Deputy 
Assistant Secretary for Acquisition and Materiel Management will, when 
necessary, forward the notice required by FAR 10.007(a)(4) to the 
General Services Administration.
    (2) Marketing center. When the essential needs of the Department of 
Veterans Affairs are not adequately covered by an existing Federal 
specification, the Chief of the Marketing Division concerned will:
    (i) Document the reasons why the deviation is essential, and obtain 
the approval of the Director, VA Marketing Center, who will report the 
approval to the Deputy Assistant Secretary for Acquisition and Materiel 
Management.
    (ii) When the required deviation affects other than packing, 
packaging, marking, or labeling, coordinate the required deviation with 
the using service in Central Office. If approved by the using service, a 
request for authority to deviate will be submitted to the Deputy 
Assistant Secretary for Acquisition and Materiel Management through the 
Director, VA Marketing Center, Hines, Ill. It will specify in detail why 
the specific deviation is essential to the Department of Veterans 
Affairs' operations and be accompanied by a copy of the using service's 
comments. The appropriate marketing division chief will be advised as to 
the approval or disapproval of the request. If approved, the Deputy 
Assistant Secretary for Acquisition and Materiel Management will when 
necessary forward the notice required by FAR 10.007(a)(4) to the General 
Services Administration.
[49 FR 12597, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989; 
54 FR 40063, Sept. 29, 1989; 61 FR 20492, May 7, 1996]



810.011  Solicitation provisions and contract clauses.

    Specifications. When product specifications are cited in an 
invitation for bids or requests for proposals, the citation shall 
include: (1) desired options, (2) deviations authorized in accordance 
with 810.007, listed in numerical sequence, and (3) shall conform to the 
following:

    Shall be type ______, grade ______, in accordance with (type of 
specification) No. ______, dated ____________ and amendment ______ dated 
____________, except paragraphs ______ and ______ which are amended as 
follows.
[49 FR 12597, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985; 54 
FR 40063, Sept. 29, 1989]



PART 812--CONTRACT DELIVERY OR PERFORMANCE--Table of Contents




            Subpart 812.1--Delivery or Performance Schedules

Sec.
812.104  Contract clauses.

                    Subpart 812.2--Liquidated Damages

812.202  Policy.
812.204  Contract clauses.

         Subpart 812.3--Priorities, Allocations, and Allotments

812.302  General.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12598, Mar. 29, 1984, unless otherwise noted.



            Subpart 812.1--Delivery or Performance Schedules



812.104  Contract clauses.

    When delivery is required by or on a particular date, the time of 
delivery clause set forth in FAR 52.212-1 as it relates to f.o.b. 
destination contracts will state that the delivery date specified is the 
date by which the shipment is to be delivered, not the shipping date. In 
f.o.b. origin contracts, the clause will state that the date specified 
is the date shipment is to be accepted by the carrier.

[[Page 171]]



                    Subpart 812.2--Liquidated Damages



812.202  Policy.

    Liquidated damages provisions will not be routinely included in 
supply or construction contracts, regardless of dollar amount. The 
decision to include liquidated damages provisions will conform to the 
criteria in FAR 12.202. In making this decision, consideration will be 
given to whether the necessity for timely delivery or performance as 
required in the contract schedule is so critical that a probable 
increase in contract price is justified. Liquidated damages provisions 
will not be included as insurance against selection of a non-responsible 
bidder, as a substitute for efficient contract administration, or as a 
penalty for failure to perform on time.



812.204  Contract clauses.

    When the liquidated damages clause prescribed in FAR 52.212-4 and 
52.212-5 is to be used and where partial performance may be utilized to 
the advantage of the Government, the clause in 852.212-70 will be 
included in the contract.



         Subpart 812.3--Priorities, Allocations, and Allotments



812.302  General.

    (a) Priorities, allocations, and allotments of critical materials 
are controlled by the Department of Commerce. Essentially such 
priorities, etc., are restricted to projects having a direct connection 
with supporting current defense needs. The Department of Veterans 
Affairs is not authorized to assign a priority rating to its purchase 
orders or contracts involving the acquisition or use of critical 
materials.
    (b) In those instances where it has been technically established 
that it is not feasible to use a substitute material, the Department of 
Commerce has agreed to assist us in obtaining critical materials for 
maintenance and repair projects. They will also, where possible, render 
assistance in connection with the purchase of new items, which may be in 
short supply because of their use in connection with the defense effort.
    (c) Contracting officers having problems in acquiring critical 
materials will ascertain all the facts necessary to enable the 
Department of Commerce to render assistance to the Department of 
Veterans Affairs in acquiring these materials. The contracting officer 
will submit a request for assistance containing the following 
information to the Deputy Assistant Secretary for Acquisition and 
Materiel Management (90):
    (1) A description of the maintenance and repair project or the new 
item, whichever is applicable.
    (2) The critical material and the amount required.
    (3) The contractor's sources of supply including any addresses. If 
the source is other than the manufacturer or producer, also list the 
name and address of the manufacturer or producer.
    (4) The Department of Veterans Affairs contract or purchase order 
number.
    (5) The contractor's purchase order number, if known, and the 
delivery time requirement as stated in the solicitation or offer.
    (6) The additional time the contractor claims will be necessary to 
effect delivery if priority assistance is not provided.
    (7) The nature and extent of the emergency that will be generated at 
the station, e.g., (i) damage to the physical plant, (ii) impairment of 
the patient care program, (iii) creation of safety hazards, and (iv) any 
other pertinent condition that will result because of failure to secure 
assistance in obtaining the critical materials.
    (8) If applicable, a statement that the item required is for use in 
a construction contract which was authorized by the Deputy Assistant 
Secretary for Facilities (08), to be awarded and administered by the 
facility contracting officer.
[49 FR 12598, Mar. 29, 1984, as amended at 54 FR 40063, Sept. 29, 1989]

[[Page 172]]



          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES





PART 813--SMALL PURCHASE AND OTHER SIMPLIFIED PURCHASE PROCEDURES--Table of Contents




                     Subpart 813.5--Purchase Orders

Sec.
813.505-2  Agency forms in lieu of Optional Forms 347 and 348.
813.506-70  Oral purchase orders.
813.507  Clauses.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).



                     Subpart 813.5--Purchase Orders



813.505-2  Agency forms in lieu of Optional Forms 347 and 348.

    (a) VA Form 90-2138, Order for Supplies or Services, and VA Form 90-
2139, Order for Supplies or Services (Continuation), provide in one 
interleaved set of forms a purchase or delivery order, vendor's invoice, 
and receiving report. They will be used in lieu of and in the same 
manner as Optional Form 347, Order for Supplies or Services and Optional 
Form 348, Order for Supplies or Services Schedule--Continuation.
    (b) The following order forms are for use when ordering the 
indicated medical, dental and ancillary services up to $10,000 per 
authorization when such services are not available under existing 
contracts.
    (1) VA Form 10-7078, Authorization and Invoice for Medical and 
Hospital Services.
    (2) VA Form 10-7079, Request for Outpatient Medical Services.
    (3) VA Form 10-2570d, Dental Record, Authorization and Invoice for 
Outpatient Services.
    (c) In authorizing patient travel as set forth in VA Manual MP-1, 
Part II, Chapter 3, VA Form 10-2511, Authority and Invoice for Travel by 
Ambulance or Other Hired Vehicle, will be used as provided by that 
manual.
    (d) Standard Form 182, Request, Authorization, Agreement, and 
Certification of Training, will be utilized for the procurement of 
training in the manner prescribed in 870.104.
    (e) VA Form 10-2421, Prosthetics Authorization and Invoice, will be 
used as prescribed in 801.670-15 for indicated services not in excess of 
$300.
[49 FR 12599, Mar. 29, 1984]



813.506-70  Oral purchase orders.

    Oral purchase orders, when considered advantageous to the Department 
of Veterans Affairs, may be used for transactions not in excess of 
$2,500. This limitation does not apply to delivery orders against 
existing contracts, e.g., delivery orders against FSS Contracts. The 
transaction will be assigned a purchase order number and receipt 
documentation will be obtained on the copies of the purchase request 
utilized as a property voucher and receiving report. Documentation as to 
competition will be in accordance with FAR 13.106c.
[52 FR 28560, July 31, 1987]



813.507  Clauses.

    When using VA Form 90-2138 for maintenance contracts involving 
services performed on Government property and which have the potential 
for property damage and liability claims, the Contractor's 
Responsibilities clause found in 852.237-70 will be attached. Applicable 
maintenance contracts include but are not limited to window washing, 
pest control and elevator maintenance.
[49 FR 12599, Mar. 29, 1984]



PART 814--SEALED BIDDING--Table of Contents




                  Subpart 814.1--Use of Sealed Bidding

Sec.
814.103  Policy.
814.103-1  General.
814.104  Types of contracts.
814.104-70  Fixed-price contracts with escalation.

                   Subpart 814.2--Solicitation of Bids

814.201  Preparation of invitations for bids.
814.202  General rules for solicitation of bids.
814.202-4  Bid samples.
814.203  Methods of soliciting bids.

[[Page 173]]

814.203-1  Mailing or delivery to prospective bidders.
814.204  Records of invitations for bids and records of bids.
814.205  Solicitation mailing lists.
814.205-1  Establishment of lists.
814.205-2  Removal of names from solicitation mailing lists.
814.205-5  Release of solicitation mailing lists.
814.208  Amendment of invitation for bids (construction).

                    Subpart 814.3--Submission of Bids

814.301  Responsiveness of bids.
814.302  Bid submission.
814.304  Late bids, late modifications of bids, or late withdrawal of 
          bids.
814.304-2  Notification to late bidders.
814.304-4  Records.

          Subpart 814.4--Opening of Bids and Award of Contract

814.402  Opening of bids.
814.403  Recording of bids.
814.404  Rejection of bids.
814.404-1  Cancellation of invitations after opening.
814.404-2  Rejection of individual bids.
814.404-70  Questions involving the responsiveness of a bid.
814.406  Mistakes in bids.
814.406-3  Other mistakes disclosed before award.
814.406-4  Mistakes after award.
814.407  Award.
814.407-70  Award when only one bid is received.
814.407-71  Recommendation for award (construction).
814.408  Information to bidders.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12599, Mar. 29, 1984, unless otherwise noted.



                  Subpart 814.1--Use of Sealed Bidding



814.103  Policy.



814.103-1  General.

    Contracts in excess of the small purchase limitation or in excess of 
$1,000 for contracts made for repairs to property acquired by the 
Department of Veterans Affairs under chapter 37, title 38, United States 
Code, will be made by sealed bidding when all of the elements necessary 
for sealed bidding as prescribed in FAR 6.401(a) are present.
[51 FR 23068, June 25, 1986, and 52 FR 28559, July 31, 1987, as amended 
at 54 FR 40063, Sept. 29, 1989]



814.104  Types of contracts.



814.104-70  Fixed-price contracts with escalation.

    When contracts of this nature are authorized pursuant to 816.102(b), 
contracting officers will be guided by the provisions of FAR 16.203.



                   Subpart 814.2--Solicitation of Bids



814.201  Preparation of invitations for bids.

    (a) Invitations for bids for supplies, equipment and services will 
be serially numbered at the time of issue. The number will consist of 
the station or marketing division number, the serial number of the 
invitation, and the fiscal year in which issued, e.g., 101-24-84. A 
series beginning with the number 1 will be started each fiscal year. 
Invitations for bids for supplies, equipment and services which are 
issued, accepted and become contracts in the same fiscal year but, 
because of procurement leadtime, will not be performed until the ensuing 
fiscal year will be numbered in the series of the year in which they are 
issued. However, invitations issued in one fiscal year that will result 
in a contract that will become effective and performed only in the 
ensuing fiscal year will be numbered in the ensuing fiscal year series.
    (b) Invitations for construction contracts will bear the applicable 
IFB number and project number, if assigned.
    (c) In order to preclude adverse criticism of the Department of 
Veterans Affairs by prospective bidders relative to the disclosure of 
bid prices prior to bid opening, the provision entitled ``Caution to 
Bidders Bid-Envelopes,'' as set forth in 852.214-70, will be prominently 
placed in all invitations for bids.
    (d) To realize the greatest possible price advantage for the 
Government, items that may be processed by a contractor to effect a 
reduction in cost factors such as production, inspection and delivery, 
may be listed for award

[[Page 174]]

on both individual item and summary item bases. Items will be listed 
individually and, in addition, a summary price will be solicited for 
those items the contracting officer determines to be of a related 
character and normally handled by a majority of prospective bidders.
    (1) When different products are to be combined for a summary price, 
the quantity, unit and unit price columns opposite the summary item will 
be crossed out, e.g.:

(Item No.) Summary bid for furnishing items ______ to ______ inclusive 
on an all or none basis:

                                                                                                                
----------------------------------------------------------------------------------------------------------------
               Quantity                          Unit                  Unit Price                Summary        
----------------------------------------------------------------------------------------------------------------
XX...................................  XX.....................  XX.....................  $ XX                   
----------------------------------------------------------------------------------------------------------------
(Bidder will enter summary amount.)                                                                             


    (2) When a single unit price is solicited for a single product for 
delivery to various destinations, or for multiple deliveries, the total 
quantity required will be listed opposite the summary item, e.g.:

(Item No.) Summary bid for furnishing items ______ to ______ inclusive 
on all or none basis:

                                                                                                                
----------------------------------------------------------------------------------------------------------------
               Quantity                          Unit                  Unit Price                Summary        
----------------------------------------------------------------------------------------------------------------
XX...................................  XX.....................  XX.....................  $ XX                   
----------------------------------------------------------------------------------------------------------------
(Bidder will enter unit price and summary amount.)                                                              


    (3) Invitations containing a summary bid request will contain the 
following statement:

    The award will be made on either an individual item basis or summary 
bid basis, whichever results in the lowest cost to the Government. 
Therefore, to assure proper evaluation of all bids, a bidder quoting a 
summary bid price must also quote a price on each individual item 
included in the summary bid price.

    (e) Bid invitations for supplies, equipment, or services (other than 
construction) must define the extent to which alternate bids will be 
authorized and considered. Alternates specified on construction projects 
will be considered for acceptance only as a part of the basic item.
    (1) When an alternate item will be considered only if no bids or 
insufficient bids are received on the item desired, the clause set forth 
in 852.214-71(a) will be included in the invitation.
    (2) When an alternate item will be considered on an equal basis with 
the item specified, the clause set forth in 852.214-71(b) will be 
included in the invitation.
    (3) In addition to the clauses referenced in paragraph (e) (1) or 
(2) of this section, the clause set forth in 852.214-71(c) will be 
included in the invitation when bids will be allowed on different 
packaging, unit designation, etc.
    (f) When a contracting officer determines that it will be 
advantageous to the Government to make the award by group or groups of 
items, a provision for such award will be included in the invitation for 
bids.
    (1) This may apply when:
    (i) The items in the group or groups are readily available from the 
sources to be solicited; and
    (ii) It is desirable to make a minimum number of contracts; or
    (iii) Furniture or fixtures are required for a single project and 
uniformity of design is desirable; or
    (iv) The articles required will be assembled and used as a unit.
    (2) Solicitations for supplies and services, other than 
construction, will contain the provision set forth in FAR 52.214-22.
    (3) Solicitations for construction contracts which solicit prices on 
an item and alternate item basis (when it is intended that a single 
aggregate award will be made for all items in the solicitation within 
certain fiscal limitations) will contain a statement as to the order of 
priority in which the alternate items will be awarded. This priority 
will be based on the relative importance of an item, the Department of 
Veterans Affairs' estimate, and the amount of funds available. Such 
schedules will be substantially as follows:

    Item No. 1--Furnish all labor, material, equipment, etc., to paint 
buildings No. 1, 2, and 3, $______.
    Alternate items in order of priority. Furnish all labor, material, 
equipment, etc., to paint:
    Item No. 2--Building No. 1 only $______.
    Item No. 3--Building No. 2 only $______.


A single award will be made on Item No. 1, but in the event the offer 
exceeds

[[Page 175]]

the funds available, a single award will be made on Item No. 2, or a 
combination of Item Nos. 2 and 3. Offerors should quote a price on each 
item listed.
[49 FR 12599, Mar. 29, 1984, as amended at 50 FR 791, Jan. 7, 1985; 51 
FR 23068, June 25, 1986; 52 FR 28559, July 31, 1987; 52 FR 49017, Dec. 
29, 1987; 54 FR 30044, July 18, 1989]



814.202  General rules for solicitation of bids.



814.202-4  Bid samples.

    When it has been determined that samples are necessary to the proper 
awarding of a contract, the provision set forth in 852.214-73 will be 
added to the provision in FAR 52.214-20.
[49 FR 12599, Mar. 29, 1984, as amended at 52 FR 49017, Dec. 29, 1987]



814.203  Methods of soliciting bids.



814.203-1  Mailing or delivery to prospective bidders.

    The contracting officer will include either a bid envelope, or 
Optional Form 17, Sealed Bid Label, with each invitation for bids 
furnished to prospective bidders.
[49 FR 12599, Mar. 29, 1984, as amended at 51 FR 23068, June 25, 1986; 
52 FR 28559, July 31, 1987; 58 FR 48974, Sept. 21, 1993]



814.204  Records of invitations for bids and records of bids.

    (a) A single register will be established and maintained by the 
issuing office on a fiscal year basis for all solicitations by 
invitations for bid or requests for proposal number, date of issue, date 
of opening, commodity or service involved and disposition, i.e., 
contract number or purchase order number or, when applicable, no award.
    (b) Maintenance of the contract file prescribed by part 804 and 
retention of canceled Invitation for Bid files will fulfill the 
requirements set forth in FAR 14.204.



814.205  Solicitation mailing lists.



814.205-1  Establishment of lists.

    From the solicitations mailing list applications received, each 
contracting activity will compile and keep current a Solicitations 
Mailing List file. The lists will be maintained according to the 
commodity classification or group of items normally listed on the same 
invitation for bids.
[49 FR 12599, Mar. 29, 1984, as amended at 51 FR 23068, June 25, 1986; 
52 FR 28559, July 31, 1987]



814.205-2  Removal of names from solicitation mailing lists.

    Except as provided for in FAR 14.205-2, no Department of Veterans 
Affairs contracting officer, or other employee, shall remove from the 
solicitation mailing list the name of any prospective solicitation.
[49 FR 12599, Mar. 29, 1984, as amended at 51 FR 23068, June 25, 1986; 
52 FR 28559, July 31, 1987]



814.205-5  Release of solicitation mailing lists.

    When invitations for bids for supply and service contracts have been 
issued, contracting officers may furnish, upon request of an individual 
or institution having a bona fide interest in such information, a list 
of the prospective bidders to whom invitations for bids were submitted. 
The provisions of FAR 14.205-5 will be observed with respect to 
invitations for bids for construction contracts.



814.208  Amendment of invitation for bids (construction).

    Amendments will be sent to holders of drawings and specifications by 
certified mail, return receipt requested. (Amendments may be made by 
telegram, if time does not permit mailing.)



                    Subpart 814.3--Submission of Bids



814.301  Responsiveness of bids.

    Where the timeliness of the submission of a bid, modification or 
withdrawal cannot be administratively determined in accordance with FAR 
14.301, the matter will be submitted by the contracting officer directly 
to the Comptroller General for decision. The submission will include 
copies of all pertinent papers. A copy of each submission will be 
forwarded to the Deputy Assistant Secretary for Acquisition and Materiel 
Management.

[[Page 176]]



814.302  Bid submission.

    A bid hand-carried by the bidder or his agent will be considered 
late unless delivered to the addressee designated in the bid invitation 
prior to the time set for opening.
[49 FR 12599, Mar. 29, 1985, as amended at 50 FR 791, Jan. 7, 1985]



814.304  Late bids, late modifications of bids, or late withdrawal of bids.



814.304-2  Notification to late bidders.

    The notification to late bidders will specify the final date by 
which the evidence must be received to be considered. This date must be 
within the time allowed by the apparent low bidder for acceptance of his 
bid.



814.304-4  Records.

    All bids received by mail (or telegram where authorized) will be 
time and date stamped immediately upon receipt at VA installation mail 
room and in the office of the addressee designated in the invitation. 
This will firmly establish the time of receipt of bids, or when bids are 
received in the office of the addressee subsequent to the time of 
opening, and it will establish whether or not the delay was due to 
mishandling on the part of VA.
[49 FR 12599, Mar. 29, 1984, as amended at 54 FR 40063, Sept. 29, 1989]



          Subpart 814.4--Opening of Bids and Award of Contract



814.402  Opening of bids.

    (a) The contracting officer shall serve as, or designate, a bid 
opening officer, and shall also designate a recorder.
    (b) The form and amount of bid security and name of surety will be 
read aloud and recorded.
[49 FR 12599, Mar. 29, 1985, as amended at 50 FR 792, Jan. 7, 1985]



814.403  Recording of bids.

    The information required for bid evaluation shall be recorded on the 
appropriate Abstract of Offers form (SF 1409 or SF 1419). The evaluation 
data may be recorded on supplemental sheets or forms such as VA Form 10-
2237b, Request for Dietetic Supplies, providing that such supplemental 
sheets or forms are covered by one of the forms authorized above for 
recording bid or price data. In addition to those instructions set forth 
in FAR 14.403, the bid opening officer shall certify on the abstract the 
date and hour at which the bids were opened. Where erasures, 
strikeovers, or changes in price are noted at the time of opening, a 
statement to that effect will also be included on, or attached to, the 
abstract or record of bids.
[49 FR 12599, Mar. 29, 1985, as amended at 61 FR 11586, Mar. 21, 1996]



814.404  Rejection of bids.



814.404-1  Cancellation of invitations after opening.

    (a) A copy of each invitation for bids which is canceled as provided 
for in FAR 14.404-1, together with the abstract showing to whom such 
bids were sent, will be filed in a separate folder identified by the 
invitation number. Invitations for bids which result in no bids being 
received will be handled in like manner. In each instance the abstract 
will be annotated to show why an award was not made. These folders will 
be retained for the current and two succeeding fiscal years.
    (b) The authority to approve cancellation of invitations for bid 
after opening and the authority to approve the acquisition after 
cancellation as provided in FAR 14.404-1(e) is delegated to the head of 
the contracting activity. The contracting officer will submit a D&F 
prepared as prescribed in Subpart 801.7 to the head of the contracting 
activity for signature.
[49 FR 12599, Mar. 29, 1984, as amended at 51 FR 23068, June 25, 1986; 
52 FR 28560, July 31, 1987]



814.404-2  Rejection of individual bids.

    (a) When a bid that is being considered for an award is found to be 
incomplete, e.g., all pages of the invitation have not been returned by 
the bidder, the contracting officer will take whichever of the following 
actions that is appropriate:
    (1) Make a determination that the bid as submitted is in such a form 
that acceptance would create a valid and

[[Page 177]]

binding contract, requiring the contractor to perform in accordance with 
all of the material terms and conditions of the invitation. Such a 
determination may be based on the fact that the bid as submitted 
includes evidence that the offeror intends to be bound by all the 
material terms and conditions of the invitation.
    (2) Make a determination that the bid as submitted is in such form 
that acceptance would not create a valid and binding contract.
    (b) When a single bid is received in response to a solicitation, the 
offer shall not be rejected simply because it specifies a bid acceptance 
time which is shorter than that contained in the solicitation, unless a 
compelling reason exists for rejecting such a bid. Insufficient time to 
properly evaluate an offer shall be considered a compelling reason for 
rejection; however, the contracting officer will first request the 
offeror to extend the acceptance date of the bid to allow for proper 
evaluation.

    Note: In those cases where more than one bid is received, an 
individual bid which is not in compliance with the Government's bid 
acceptance time shall be rejected as nonresponsive since consideration 
of such an offer would unfairly disadvantage other bidders.



814.404-70  Questions involving the responsiveness of a bid.

    Questions involving the responsiveness of a bid which cannot be 
resolved by the contracting officer may be submitted to the Comptroller 
General through the Deputy Assistant Secretary for Acquisition and 
Materiel Management, Acquisition Review Division, or the Chief 
Facilities Management Officer, Office of Facilities Management, as 
appropriate. Pertinent documentation must accompany the submission.
[49 FR 12599, Mar. 29, 1984, as amended at 54 FR 40063, Sept. 29, 1989; 
61 FR 11586, Mar. 21, 1996]



814.406  Mistakes in bids.



814.406-3  Other mistakes disclosed before award.

    (a) In accordance with the provisions of the FAR 14.406-3(e), the 
authority of the Secretary to make the administrative determinations set 
forth in FAR 14.406-3 (a), (b), (c), and (d) is hereby delegated, 
without power of redelegation to the Deputy Assistant Secretary for 
Acquisition and Materiel Management. This delegation in no way impairs 
the delegations contained in Comptroller General decision B-122003, 
dated November 22, 1954.
    (b) When a bidder alleges a mistake in his or her bid prior to 
award, after complying with the provisions of FAR 14.406-3, the 
contracting officer will submit the complete file to the Deputy 
Assistant Secretary for Acquisition and Materiel Management, Acquisition 
Review Division for an administrative determination. Based upon the 
evidence submitted, the Deputy Assistant Secretary for Acquisition and 
Materiel Management will determine the action to be taken by the 
contracting officer. Prior to its release to the contracting officer, 
this determination will be submitted to the General Counsel (025) for 
approval. Pending receipt of the determination, no award shall be made.
    (c) Based on the evidence, when the Deputy Assistant Secretary for 
Acquisition and Materiel Management believes that the case should be 
submitted to the Comptroller General for decision, he/she will prepare 
the submission and forward it to the Comptroller General through the 
General Counsel (025). The decision of the Comptroller General will be 
furnished to the contracting officer by the Deputy Assistant Secretary 
for Acquisition and Materiel Management, Acquisition Review Division. A 
copy of each such decision will be furnished to the General Counsel 
(025).
[49 FR 12599, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989; 
61 FR 11586, Mar. 21, 1996]



814.406-4  Mistakes after award.

    (a) When a contracting officer corrects a mistake in bid pursuant to 
FAR 14.406-4(a), a copy of the contract amendment or supplemental 
agreement together with a copy of the contracting officer's 
determination will be forwarded to the Deputy Assistant Secretary for 
Acquisition and Materiel Management, Acquisition Review Division.

[[Page 178]]

    (b) For mistakes in bid alleged after award, the contracting 
officer's proposed determination, prepared in accordance with FAR 
14.406-4, will be forwarded to the General Counsel (025) through the 
Deputy Assistant Secretary for Acquisition and Materiel Management, 
Acquisition Review Division for legal coordination. The results of this 
coordination will be transmitted to the contracting officer by the 
Deputy Assistant Secretary for Acquisition and Materiel Management, 
Acquisition Review Division. The final determination on the alleged 
mistake in bid after award will be made by the contracting officer.
    (c) The Deputy Assistant Secretary for Acquisition and Materiel 
Management, Acquisition Review Division will maintain the agency records 
of mistakes in bids after award required by FAR 14.406-4.
[49 FR 12599, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989, 
as amended at 61 FR 11586, Mar. 21, 1996]



814.407  Award.



814.407-70  Award when only one bid is received.

    When only one bid is received in response to an invitation for bids, 
such bid may be considered and accepted if (a) the specifications used 
in the invitation were not restrictive, (b) adequate competition was 
solicited, (c) the price is reasonable, and (d) the bid is otherwise in 
accordance with the invitation for bids. Such determination will be made 
in writing, and included on or attached to the abstract of bids.



814.407-71  Recommendation for award (construction).

    (a) For Central Office contracts, the Chief Facilities Management 
Officer, Office of Facilities Management, after analyzing all bids 
received, will submit a memorandum to the Secretary (00) recommending 
award or other disposition of the project. A copy of each of the 
following will accompany the memorandum:
    (1) The invitation.
    (2) Each bid received.
    (3) The abstract.
    (4) Any other pertinent data.
    (b) On facility level contracts, the Chief, Engineering Service, 
will analyze all bids received and submit to the contracting officer a 
memorandum recommending award or other disposition of the project. 
However, the final decision to accept or reject the lowest responsive 
bid and the determination as to the responsibility of a prospective 
contractor shall be made by the contracting officer alone.
[49 FR 12599, Mar. 29, 1984, as amended at 54 FR 30044, July 18, 1989; 
54 FR 40063, Sept. 29, 1989; 61 FR 11586, Mar. 21, 1996]



814.408  Information to bidders.

    (a) Prior to award, no information as to probable acceptance or 
rejection of any offer shall be given to any bidder or other person 
outside the Department of Veterans Affairs.
    (b) Except as provided in paragraphs (c) and (d) of this section, 
information as to performance under contract or an accepted bid is not 
public information and will be released to persons outside VA only upon 
the authority of the immediate supervisor of the contracting officer.
    (c) Except as provided in paragraph (d) of this section, the 
contracting officer may furnish information as to performance under a 
contract to those having a legitimate interest, such as banks, other 
financial companies and Government departments and agencies.
    (d) When litigation is involved, all information will be furnished 
through the General Counsel (025).
[49 FR 12599, Mar. 29, 1984, as amended at 54 FR 30045, July 18, 1989; 
54 FR 40063, Sept. 29, 1989]



PART 815--CONTRACTING BY NEGOTIATION--Table of Contents




                  Subpart 815.5--Unsolicited Proposals

Sec.
815.504  Advance guidance.
815.506  Department procedures.
815.506-1  Receipt and initial review.

                     Subpart 815.6--Source Selection

815.607  Disclosure of mistakes before award.

                    Subpart 815.8--Price Negotiation

815.804-70  Preproduction and start-up and other nonrecurring costs.

[[Page 179]]

815.805-4  Technical analysis.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12604, Mar. 29, 1984, unless otherwise noted.



                  Subpart 815.5--Unsolicited Proposals

    Source:  51 FR 6005, Feb. 19, 1986, unless otherwise noted.



815.504  Advance guidance.

    (a) Any inquiries from a potential offeror of an unsolicited 
proposal shall be referred to the appropriate VA contact point 
designated in 815.506(a). The contact point will determine the nature of 
the potential proposal and determine what technical/professional 
disciplines need be consulted to determine the VA need for such a 
proposal and the likelihood that a formal proposal would be favorably 
reviewed. In consultation with such technical/professional offices, the 
VA contact point will inform the potential proposer of any additional 
information required to provide advance guidance as well as the 
information specified in FAR 15.504.
    (b) The FAR contact point will maintain a record of advance guidance 
provided and the disposition/recommendation regarding the potential 
offer.



815.506  Department procedures.

    (a) The Chief, Acquisition and Materiel Management Service, 
servicing the field facility and the Director, VA Marketing Center, 
Hines, Illinois are designated as the VA contact points for unsolicited 
proposals submitted at the facility level. The Deputy Assistant 
Secretary for Acquisition and Materiel Management is designated as the 
VA contact point for all unsolicited proposals received at VA Central 
Office.
    (b) Each unsolicited proposal received by the Department of Veterans 
Affairs will be submitted to the appropriate contact point.
    (c) The VA contact point will review the unsolicited proposal and 
ensure that it is complete as prescribed in FAR 15.505. If required 
information is not submitted, the VA contact point will:
    (1) Determine if advance guidance as specified in FAR 15.504 is 
necessary (2) request that the offeror provide the necessary information 
if it is determined that the formal evaluation prescribed in FAR 15.506-
2 is appropriate; and (3) establish an estimated due date for completion 
of the review process.
[51 FR 6005, Feb. 19, 1986, as amended at 54 FR 40063, Sept. 29, 1989; 
54 FR 42508, Oct. 17, 1989]



815.506-1  Receipt and initial review.

    (a) When VA contact point determines that a comprehensive evaluation 
is to be undertaken (i.e., the proposal complies with the requirements 
in FAR 15.506-1(a) and is related to the mission of VA), the offeror 
will be contacted to ensure that all data that should be restricted in 
accordance with FAR 15.509 has been identified.
    (b) The VA contact point will maintain a log of all unsolicited 
proposals which will be evaluated. The log will indicate:
    (1) The date the proposal was received;
    (2) The date that the unsolicited proposal has been determined to 
warrant a comprehensive evaluation;
    (3) A description of the proposal;
    (4) The offices requested to evaluate the proposal and the date such 
offices are requested to return their evaluations;
    (5) The date the reviewing offices finalize their respective 
evaluation; and
    (6) The final disposition of the proposal.
    (c) Each office which is assigned responsibility for reviewing an 
unsolicited proposal will be advised of the need to evaluate the 
proposal against the criteria set forth in FAR 15.507(a) (1) through 
(3), i.e., is the proposal available to the Government without 
restriction from another source, does it closely resemble a pending 
competitive acquisition, is the proposal lacking in demonstrated 
innovation or uniqueness? If the reviewers conclude in the affirmative 
as to any one of these questions, the VA contact point shall be advised 
and return the proposal to the proposer.
    (d) With regard to an unsolicited proposal being processed at a 
field facility, if the reviewing offices conclude that

[[Page 180]]

the unsolicited proposal should be accepted and provide the 
justification and certification required by FAR 15.507, the VA contact 
point will obtain the prior approval of the Deputy Assistant Secretary 
for Acquisition and Materiel Management (93) prior to proceeding with 
negotiation. In order to obtain the approval, the VA contact point will 
submit all necessary documentation supporting the noncompetitive 
negotiation including any justification and approval required by FAR 
Subpart 6.3 and results of any synopsis required by FAR Subpart 5.2 The 
Deputy Assistant Secretary for Acquisition and Materiel Management will 
coordinate the proposal with the cognizant VA Central Office program 
official(s) and furnish the VA contact point with the final decision.
    (e) All copies of the unsolicited proposal will be controlled by the 
contact point by numbering each copy. If a reviewing office requires 
additional copies, the reviewing office will obtain approval of the VA 
contact point prior to duplication, numbering the copies as specified by 
the contact point. All copies will be returned to the VA contact point 
once review is completed.
[51 FR 6005, Feb. 19, 1986, as amended at 54 FR 40063, Sept. 29, 1989]



                     Subpart 815.6--Source Selection



815.607  Disclosure of mistakes before award.

    The Head of the Contracting Activity (as defined in 802.1) is 
delegated authority to permit correction of mistakes in proposals before 
award consistent with FAR 15.607.
[54 FR 45736, Oct. 31, 1989]



                    Subpart 815.8--Price Negotiation



815.804-70  Preproduction and start-up and other nonrecurring costs.

    In evaluating start-up and other nonrecurring costs, the extent to 
which these costs are included in the proposed price and the intent to 
absorb or recover any such costs in any future noncompetitive 
procurement or other pricing action will be determined. The contracting 
officer will ascertain, with the assistance of the Assistant Inspector 
General for Policy, Planning and Resources (53), as required or 
considered necessary, that payment of such costs is not duplicated. For 
example, cost of equipment paid for by the Government through a setup or 
connection agreement will not be included in depreciation costs of a 
subsequently negotiated agreement.
[49 FR 12604, Mar. 29, 1984, as amended at 50 FR 792, Jan. 7, 1985; 54 
FR 40063, Sept. 29, 1989]



815.805-4  Technical analysis.

    (a) Contracting officers are responsible for the technical and 
administrative sufficiency of the contracts they enter into and ensuring 
that all legal and technical reviews are accomplished. To this end, 
initial and revised pricing of all negotiated prime contracts (including 
subcontract pricing under them) and contract modifications will be 
subject to technical analyses to the degree the contracting officer 
deems necessary (see 801.602-70 for required legal reviews). Technical 
analyses of the proposals will be requested by the contracting officer 
from the appropriate technical personnel to address, as a minimum, the 
items set forth in FAR Subpart 15.805-4. Contracting officers shall not 
begin negotiation of or award any negotiated contracts or contract 
modifications before receipt, analysis and consideration of documented 
technical evaluations for every procurement action requiring such 
analysis under the conditions prescribed in FAR 15.805-4. The results of 
such analyses will be documented in the contract file and will also be 
made available to the auditor performing the preaward audit required by 
815.805-5.
    (b) When, in the opinion of the contracting officer, the complexity 
of the proposed contract warrants, he/she will submit the proposed 
contract to the Deputy Assistant Secretary for Acquisition and Materiel 
Management (93) for review and comment. When deemed advisable, the 
Deputy Assistant Secretary for Acquisition and Materiel Management (93) 
will request the General Counsel to accomplish a legal review. This 
review is in addition to the legal review specified in 801.602-70.

[[Page 181]]



PART 816--TYPES OF CONTRACTS--Table of Contents




                 Subpart 816.1--Selecting Contract Types

Sec.
816.102  Policies.

                 Subpart 816.70--Unauthorized Agreements

816.7001  Letters of availability.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).



                 Subpart 816.1--Selecting Contract Types



816.102  Policies.

    (a) Contracts which include an economic price adjustment provision 
other than those contracts awarded by the National Cemetery System for 
monuments or those contracts that contain the clause for service 
contracts (FAR 22.1006(c)) require the prior approval of the Deputy 
Assistant Secretary for Acquisition and Materiel Management (90). The 
request for approval shall clearly set forth the need for the provision.
    (b) Any contract involving direct obligation of appropriations and 
which extends beyond the appropriation of the year in which the contract 
period begins or which is for more than one fiscal year, is to contain 
provisions to the effect that:
    (1) It is made for the period covered by the contract, subject to 
the availability of appropriations in the ensuing year(s), and
    (2) No service is to be performed by the contractor after September 
30 of each fiscal year unless and until specifically authorized by the 
contracting officer or representative.
    (c) Architect-engineer contracts, construction contracts, or 
professional engineer contracts, financed by ``no year appropriations'' 
are not subject to the requirements of paragraph (b) of this section.
[49 FR 12607, Mar. 29, 1984, as amended at 50 FR 792, Jan. 7, 1985; 54 
FR 30045, July 18, 1989; 61 FR 20492, May 7, 1996]



                 Subpart 816.70--Unauthorized Agreements



816.7001  Letters of availability.

    (a) Description. A letter of availability (sometimes inappropriately 
called a letter of intent) is a letter to a supplier primarily for the 
purpose of obtaining a place on the supplier's production or delivery 
schedule for long lead time items. Such a letter typically indicates 
that products or services are being considered for procurement, but that 
the statement of intent is not to be construed as a commitment. Such 
letters of availability are sometimes solicited by prospective 
contractors, or they may be originated by Government personnel. A letter 
of availability is distinguished from a letter contract which is 
specifically authorized in FAR 16.603.
    (b) Policy. (1) Unless specifically authorized by the Deputy 
Assistant Secretary for Acquisition and Materiel Management, letters of 
availability are not to be utilized for the following reasons:
    (i) While such letters of availability may disclaim Government 
liability, they may induce potential contractors to initiate costly 
preparations in anticipation of contract award.
    (ii) Procurements announced in such letters do not always 
materialize. The result may be costly to the Government, the prospective 
contractor, or both. If the author of the letter of availability is an 
authorized contracting officer of the Department, the Government may be 
bound by action, even though the action is contrary to sound procurement 
practices and/or fiscal regulations. If the author of the letter of 
availability lacks procurement authority, the prospective contractor may 
incur substantial expenditures which may not be recovered from the 
Government, but for which the prospective contractor may seek to hold 
the unauthorized author personally liable.
    (iii) The issuance of a letter of availability may violate the 
``Anti-Deficiency Act'' (31 U.S.C. 1341).

[[Page 182]]

    (2) It is recognized that potential contractors have a need to 
obtain procurement information at the earliest possible moment in order 
to make timely preparations. To this end, procurement personnel are 
expected to act as efficiently and expeditiously as possible on all 
procurement actions.
[49 FR 12607, Mar. 29, 1974, as amended at 54 FR 30044, July 18, 1989; 
54 FR 40064, Sept. 29, 1989]



PART 817--SPECIAL CONTRACTING METHODS--Table of Contents




                  Subpart 817.1--Multi-Year Contracting

Sec.
817.102  Policy.
817.102-1  Uses.

                         Subpart 817.2--Options

817.202  Use of options.

                Subpart 817.4--Leader Company Contracting

817.402  Limitations.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12608, Mar. 29, 1984, unless otherwise noted.



                  Subpart 817.1--Multi-Year Contracting



817.102  Policy.



817.102-1  Uses.

    (a) Pursuant to Title 38, United States Code, Chapter 1, Section 114 
(as amended by Pub. L. 101-237), multiyear contracting not exceeding 5 
years is authorized for obtaining supplies and services when the 
Secretary has made the following determinations:
    (1) Appropriations are available for obligation for the total 
payments for the fiscal year the contract is entered into plus the 
estimated amount of any cancellation charges.
    (2) The contract is in the best interest of the Government due to 
the effect it would have in:
    (i) Reducing cost;
    (ii) Achieving contract administration and other efficiencies;
    (iii) Increasing quality contract performance;
    (iv) Encouraging effective competition.
    (3) During the contract period:
    (i) There is a continuing need for the supplies or services;
    (ii) There is little likelihood of substantial changes in need for 
the supplies and services in terms of quantity or rate of delivery; and
    (iii) The specifications for the supplies or services are expected 
to be reasonably stable.
    (4) The risks relating to a prospective contractor's ability to 
perform in accordance with the specifications and other contract terms 
are not excessive;
    (5) The use of a multiyear contract will not inhibit competition 
from small business firms;
    (6) In the case of a pharmaceutical item for which a patent has 
expired less than 4 years before the solicitation issue date, there is 
no substantial likelihood that increased competition will occur during 
the term of the contact that would make the contract prices higher than 
would be reasonable.
    (b) The authority of the Secretary to enter into multiyear contracts 
and to make the determinations specified in 817.102-1(a) of this section 
is delegated as follows:
    (1) Heads of contracting activities. For contracts not requiring 
legal/technical reviews pursuant to 801.602-70 (for purposes of 
determining applicability of the thresholds, the total dollar amount of 
the contract over its full multiyear term will be used), and which do 
not contain a first year cancellation ceiling which exceeds 20 percent 
of the total dollar amount of the contract over the full multi-year 
term.
    (2) Assistant Secretary for Acquisition and Materiel Management, 
will approve all proposed uses of multiyear contracts not authorized for 
approval by heads of contracting activities. For approval purposes, the 
head of the contracting activity will justify and document the use of a 
multiyear contract against each of the criteria specified in 817.102-1 
(a)(1) through (a)(6) of this section. The justification will 
additionally delineate the cancellation ceiling and the method used for 
calculating that ceiling and will specify the advantages of multiyear 
contracts over other

[[Page 183]]

alternative methods, e.g., option year contracts.
    (c) Cancellation ceilings will be carefully developed in accordance 
with FAR 17.103-1 and VAAR 817.103-1.
[54 FR 980, Jan. 11, 1989, as amended at 57 FR 44129, Sept. 24, 1992]



                         Subpart 817.2--Options



817.202  Use of options.

    All solicitations developed pursuant to Office of Management and 
Budget Circular A-76 (Revised) cost comparisons will provide for one 
year renewal options as prescribed in FAR Subpart 17.2. Requests to use 
less or more than the prescribed contract period for Circular A-76 
(Revised) cost comparisons will be forwarded to the Deputy Assistant 
Secretary for Acquisition and Material Management (90).
[49 FR 12608, Mar. 29, 1984, as amended at 54 FR 980, Jan. 11, 1989; 57 
FR 44129, Sept. 24, 1992]



                Subpart 817.4--Leader Company Contracting



817.402  Limitations.

    (a) Except as provided in 817.402(b), no leader company contracts 
shall be initiated or consummated.
    (b) The Deputy Assistant Secretary for Acquisition and Materiel 
Management (90) may designate a contracting officer to enter into a 
leader company contract when considered beneficial to the Department and 
the Government. When a contracting officer is designated the authority 
to enter into a leader company contract, the designation will be by name 
for a specific contract. The proposed contract with a determination and 
finding will be submitted for legal review in accordance with 801.602-
71.
[49 FR 12608, Mar. 29, 1984, as amended at 54 FR 980, Jan. 11, 1989; 54 
FR 40064, Sept. 29, 1989]

[[Page 184]]



                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS





PART 819--SMALL BUSINESS AND SMALL DISADVANTAGED BUSINESS CONCERNS--Table of Contents




Sec.
819.000  Scope of part.

                         Subpart 819.2--Policies

819.201  General policy.
819.202-5  Data collection and reporting requirements.
819.202-70  Additional responsibilities.

              Subpart 819.5--Set-Asides for Small Business

819.502-2  Total set-asides.
819.502-3  Partial set-asides.

    Subpart 819.6--Certificates of Competency and Determinations of 
                               Eligibility

819.602-3  Appealing Small Business Administration's decision to issue 
          Certificates of Competency.

 Subpart 819.8--Contracting With the Small Business Administration (The 
                              8(a) Program)

819.801  General.
819.803  Selecting acquisitions for the 8(a) program.
819.804  Agency evaluation of the Small Business Administration's 
          request for a commitment.
819.806-2  Estimating the current fair market price.
819.806-3  Pricing review by the Small Business Administration.
819.806-4  Funding business development expense.
819.807-70  Commitments of the Office of Facilities' funded projects for 
          the 8(a) program.
819.809-70  Procurement of supplies, services, and research and 
          development.
819.809-71  Procurement of construction.

       Subpart 819.70--Veteran-Owned and Operated Small Businesses

819.7001  Policy.
819.7002  Definition.
819.7003  Procedure.
819.7004  Waiver of the use of veteran-owned firms.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12608, Mar. 29, 1984, unless otherwise noted.



819.000  Scope of part.

    This subpart sets forth the Department of Veterans Affairs small 
business program including section 8(a) contracts with Small Business 
Administration (SBA) and unilateral set-asides. It establishes 
responsibility for making such determinations, reviewing determinations 
and evaluation of the program.
[49 FR 12608, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



                         Subpart 819.2--Policies



819.201  General policy.

    (a) The Director, Office of Small and Disadvantaged Business 
Utilization (OSDBU) (005SB) is responsible for the overall supervision 
of the Department of Veterans Affairs Small and Disadvantaged Business 
Utilization program and will assist administrations and key staff 
officials in developing their respective small business programs.
    (b) The Deputy Assistant Secretary for Facilities will develop and 
coordinate the Department small business program, as it affects 
construction projects, with the OSDBU.
    (c) The Director, Veterans Canteen Service (VCS), will designate an 
employee of his/her organization to serve as liaison between the VCS and 
the Office of Small and Disadvantaged Business Utilization on small 
business problems affecting the VCS.
    (d) The Director, National Cemetery System; Chief Benefits Director; 
Deputy Assistant Secretary for Facilities; Deputy Assistant Secretary 
for Administration; Director, Acquisition Operations Service; Director, 
VA Marketing Center; and Directors of field facilities with acquisition 
and materiel management activities will designate an employee of their 
respective organizations to serve as a small and small disadvantaged 
business specialist. This employee will be a full-time employee of the 
respective contracting activity, will be familiar with the supplies and 
services purchased at the activity, and

[[Page 185]]

will be fully cognizant of the regulations implementing the Small 
Business Act. The principal duties will include assisting the Small 
Business Administration Procurement Center Representative (if assigned) 
in activities and functions relating to sections 8 and 15 of the Small 
Business Act. The name, telephone number, and mailing symbol of each 
designee and any successor will be forwarded to the Director, Office of 
Small and Disadvantaged Business Utilization, through the Deputy 
Assistant Secretary for Acquisition and Materiel Management.
[49 FR 12608, Mar. 29, 1984, as amended at 52 FR 37317, Oct. 6, 1987; 54 
FR 40064, Sept. 29, 1989; 55 FR 49899, Dec. 3, 1990; 56 FR 44011, Sept. 
6, 1991]



819.202-5  Data collection and reporting requirements.

    Administration heads, staff office directors and heads of 
contracting activities will, in addition to the responsibilities 
designated in FAR 19.202-5, cooperate with the Office of Small and 
Disadvantaged Business Utilization in formulating specific socio-
economic procurement goals and providing other data necessary for goal 
assessment.
    (a) Each VA acquisition activity shall establish goals for 
expenditure of funds with preferred businesses within their projected 
annual budget. The preference programs supported by VA are listed in 
paragraph (c) of this section. OSDBU is responsible for Department-wide 
goals and accomplishments and will approve or adjust each acquisition 
activity's goals.
    (b) A Procurement Preference Program Goals Report (Report Control 
Symbol 00-0427) shall be submitted annually by each acquisition activity 
to reach OSDBU by November 1. Each report shall contain total 
expenditure estimates and goals for the current fiscal year and 
explanations of the methods utilized to arrive at each proposed goal.
    (c) All acquisition activities shall submit information and 
procurement preference goals identified in paragraphs (c)(1) through 
(c)(9) of this section. In addition, the Office of Acquisition and 
Materiel Management, the VA Marketing Center and the Office of 
Facilities shall submit the information identified in paragraphs (c)(1) 
through (c)(12) of this section. Goals shall be expressed in dollars and 
rounded to the nearest thousand.
    (1) Estimate of the total procurement dollar expenditures (excluding 
delivery orders against General Services Administration (GSA) FSS 
contracts).
    (2) Small business awards (includes paragraphs (c)(3) through (c)(5) 
of this section).
    (3) Minority business direct awards.
    (4) SBA 8(a) awards.
    (5) Women-owned business awards.
    (6) Labor surplus area awards.
    (7) Veteran-owned business awards (includes paragraphs (c)(8) and 
(c)(9) of this section).
    (8) Vietnam era veteran-owned business awards (including disabled 
Vietnam era veterans).
    (9) Disabled veteran-owned business awards (other than Vietnam era 
disabled veterans).
    (10) Estimate of total dollar value of subcontracts to be awarded by 
reporting prime contractors.
    (11) Subcontracts to be awarded to small business concerns by prime 
contractors.
    (12) Subcontracts to be awarded to small disadvantaged business 
concerns by prime contractors.
    (d) Anticipated problems in the attainment of the proposed goal in 
any category shall also be identified. This information will be used in 
negotiating the Department goals with SBA.
    (e) As an addendum to the report, each acquisition activity shall 
provide a narrative explaining the reason(s) for any shortfall(s) in the 
achievement of any previous fiscal year goal category. This explanation 
shall be specific and will be used by OSDBU to justify Department 
shortfalls.
    (f) Upon review by OSDBU of the proposed goals, each acquisition 
activity will be notified of the acceptance of goals as submitted, or of 
any deficiencies. If the goals are not acceptable, the acquisition 
activity will be requested to submit further written justification for 
the goals submitted. Based on documents submitted, OSDBU will make a 
final determination on the goal assignment.
    (g) Accomplishment of goals identified in paragraphs (c)(1) through 
(c)(9)

[[Page 186]]

of this section will be determined by OSDBU from data reported by 
acquisition activities into the VA Federal Procurement Data System 
(FPDS).
    (h) Achievement of subcontracting goals shall be reported by the 
Office of Facilities, the Office of Acquisition and Materiel Management, 
and the VA Marketing Center on a semiannual basis, to be received by 
OSDBU not later than April 30 for the period ending March 31, and 
November 1 for the period ending September 30.
[49 FR 12608, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989; 
55 FR 49900, Dec. 3, 1990; 56 FR 44011, Sept. 6, 1991]



819.202-70  Additional responsibilities.

    In addition to the duties designated in FAR 19.202, VA contracting 
officers will perform the following functions in furtherance of the 
small business and Labor Surplus Area (LSA) programs:
    (a) Develop a plan of operation to increase the share of contracts 
and purchase orders awarded to small business, including veteran, 
Vietnam era and disabled veteran-owned, and LSA concerns.
    (b) Promote the disadvantaged business program through the SBA 8(a) 
procedures set forth in Subpart 819.8.
    (c) Review the types and classes of items and services to be 
purchased to determine the applicability of individual small business 
set-asides and LSA set-asides. Class set-asides, established in 
accordance with criteria in FAR 19.503, shall be reviewed at least 
annually to determine whether items or services procured under a 
unilateral or joint set-aside should be modified or withdrawn. Updated 
lists of acquisitions reserved for small business on a class basis shall 
be maintained by heads of contracting activities.
    (d) On an annual basis, VA acquisition personnel shall request a 
Procurement Automated Source System (PASS) listing of veteran-owned, 
including Vietnam era and disabled, and woman-owned businesses capable 
of meeting identified requirements. Acquisition personnel will utilize 
PASS as a primary source file. Firms identified on the PASS list shall 
be included on solicitation mailing lists.
    (e) Assure that small business firms are identified on bid 
abstracts.
    (f) Assure that specifications are not unduly restrictive, thereby 
enabling small business participation to the maximum extent feasible.
    (g) Assist and counsel small business firms with individual 
problems.
    (h) Provide for counseling nonresponsive or nonresponsible small 
business bidders to help qualify them for future awards.
    (i) Attend conferences and meetings publicizing the small business 
program.
    (j) Promote the award of research contracts to small business and 
LSA firms.
    (k) Promote goals for small business, small business set-asides, 
small business subcontracting, 8(a) procurements, labor surplus area 
set-asides, and purchases from women-owned businesses.
    (l) Review all urgent and sole source procurements to determine that 
they are sparingly made, thoroughly documented and approved by the head 
of the contracting activity.
    (m) If the acquisition activity is assigned an SBA Procurement 
Center Representative (PCR), assure that the representative is provided 
logistical support, cooperation, and access to all reasonably obtainable 
contract information directly pertinent to the PCR's official duties.
    (n) Encourage technical and requirements personnel to identify 
veteran-owned and women-owned small business sources.
    (o) Assure that plans are forwarded as specified in FAR 19.705-6(b).
[49 FR 12608, Mar. 29, 1984, as amended at 50 FR 792, Jan. 7, 1985; 51 
FR 23070, June 25, 1986; 52 FR 28559, July 31, 1987; 55 FR 49900, Dec. 
3, 1990; 56 FR 44011, Sept. 6, 1991]



              Subpart 819.5--Set-Asides for Small Business



819.502-2  Total set-asides.

    (a) When a total small business set-aside is made, one of the 
following statements, as applicable, will be included in the 
solicitation for bids:
    (1) Notice of total small business set-aside, page --, applies to 
all items in this solicitation.
    (2) Notice of total small business set-aside, page --, applies to 
items -- through -- in this solicitation.

[[Page 187]]

    (b) When a total small business-LSA set-aside is made, one of the 
following statements, as applicable, will be placed on the face of the 
solicitation:
    (1) Notice of total set-aside for small business concerns agreeing 
to perform as LSA concerns, page --, applies to all items in this 
solicitation.
    (2) Notice of total set-aside for small business concerns agreeing 
to perform as LSA concerns, page --, applies to items -- through -- in 
this solicitation.
    (c) Contracting officers must ensure that appropriate product or 
service classification and the related size standard are included in 
each solicitation.
    (d) All proposed procurement for construction anticipated to cost 
between $10,000 and $3 million and all proposed procurements for 
architect-engineer services construction projects of $3 million and less 
will be considered as though SBA had initiated a set-aside request. 
Determinations of the need to deviate from this policy made by the head 
of a contracting activity will require review by the Director, Office of 
Small and Disadvantaged Business Utilization.
[49 FR 12608, Mar. 29, 1984, as amended at 50 FR 792, Jan. 7, 1985]



819.502-3  Partial set-asides.

    When, in accordance with the provisions of FAR 19.502-3, it is 
determined that a particular procurement will be partially set aside for 
exclusive small business participation or small business/labor surplus 
participation, the solicitation for bids will have appropriate product 
or service classification, appropriate size standard and whichever of 
the following statements is applicable, placed on the face page:
    (a) Notice of partial set-aside for small business concerns located 
in labor surplus areas, page --, applies to Item -- through Item -- in 
this solicitation.
    (b) Notice of partial small business set-aside, page --, applies to 
Item -- through Item -- in this solicitation.
[50 FR 792, Jan. 7, 1985]



    Subpart 819.6--Certificates of Competency and Determinations of 
                               Eligibility



819.602-3  Appealing Small Business Administration's decision to issue Certificates of Competency.

    Formal VA appeals of an initial concurrence by the SBA Central 
Office in an SBA Regional Office decision to issue a Certificate of 
Competency (CoC) will be processed as follows:
    (a) When the contracting officer believes that VA should formally 
appeal the concurrence by the SBA Central Office in an SBA Regional 
Office decision to issue a CoC, the contracting officer will so notify 
the Deputy Assistant Secretary for Acquisition and Materiel Management 
(93B) in writing within five business days after receipt of the SBA 
Central Office's written confirmation of its determination. Within ten 
business days of the contracting officer's receipt of the SBA's written 
confirmation (or within a period acceptable to VA and the SBA), the 
Deputy Assistant Secretary for Acquisition and Materiel Management (93B) 
will advise the SBA Central Office that VA intends to file a formal 
appeal.
    (b) Within ten business days of the contracting officer's receipt of 
the SBA Central Office's written confirmation, the contracting officer 
will furnish an original and one copy of the appeal file to the Deputy 
Assistant Secretary for Acquisition and Materiel Management (93B). The 
file must contain a copy of the bid/offer from the firm considered 
nonresponsible, a copy of the bid/offer from the firm otherwise in line 
for award, a copy of the bid, a copy of the bid abstract, a copy of 
SBA's CoC Review Committee report, a copy of all correspondence with SBA 
on the matter, and the contracting officer's narrative statement 
establishing the error, omission, or other basis for disputing SBA's 
proposed responsibility determination.
    (c) The Deputy Assistant Secretary for Acquisition and Materiel 
Management (93B) will review the file prepared by the contracting 
officer. If the contracting officer's position is accepted,

[[Page 188]]

the Deputy Assistant Secretary for Acquisition and Materiel Management 
(93B) will transmit the formal appeal to the SBA Central Office within 
ten business days after notifying that office of VA's intent to appeal 
(or within a period acceptable to VA and the SBA). The contracting 
officer will be informed of the final SBA decision.
    (d) If, after the Central Office review, it is decided that a formal 
appeal should not be made to the SBA, the contracting officer will be 
advised of this decision and that the CoC should be accepted by VA. The 
SBA Central Office will also be advised that VA will not pursue its 
formal appeal. If the decision concerns major construction projects and 
the Office of Facilities disagrees with the decision made by the Deputy 
Assistant Secretary for Acquisition and Materiel Management, the matter 
will be referred to the Senior Procurement Executive for a final VA 
determination.
[52 FR 46083, Dec. 4, 1987, as amended at 54 FR 40064, Sept. 29, 1989]



 Subpart 819.8--Contracting With the Small Business Administration (The 
                              8(a) Program)



819.801  General.

    (a) No contract will be entered into with SBA under section 8(a) of 
the Small Business Act (15 U.S.C. 637(a)) unless a certification is made 
by the Administrator of that agency, or designee, that SBA is competent 
to perform the contract.
    (b) When it is determined that the requirements of the Department of 
Veterans Affairs are appropriate for inclusion in this program, the 
contracting officer will make this fact known to proper officials of the 
SBA regional office servicing his/her area. However, when projects 
funded from minor construction appropriation (between $400,000 and $2 
million) are proposed for 8(a) acquisition, the Director, Office of 
Small and Disadvantaged Business Utilization (OSDBU) (005SB), shall be 
contracted by telephone or notified in writing in order to afford the 
OSDBU an opportunity to identify possible 8(a) sources prior to 
apprising SBA officials. If the certification required by paragraph (a) 
of this section is received, the Department of Veterans Affairs 
contracting officer will secure from SBA the name(s) and location(s) of 
their subcontractor(s) and the unit price(s) to be paid. Should these 
prices be within a range acceptable to the Department of Veterans 
Affairs, the contracting officer will notify SBA of acceptance.
    (c) The contract will be made between the Department of Veterans 
Affairs and SBA and will be administered by the Department of Veterans 
Affairs.
    (d) In addition to meeting the requirements of 801.602-70, 
contracting officers will secure cost and pricing data prescribed in FAR 
15.804-2 and 815.804-2 when negotiating contracts under the SBA 8(a) 
program. Contracting officers will request an audit in accordance with 
815.805-5 on proposals in excess of $500,000 before negotiating any 
contract or modification.
[49 FR 12608, Mar. 29, 1984, as amended at 50 FR 792, Jan. 7, 1985; 54 
FR 40064, Sept. 29, 1989]



819.803  Selecting acquisitions for the 8(a) program.

    The contracting officer will specify in writing the time limit for 
SBA to propose an acceptable 8(a) subcontractor. The time limit should 
be between 30 and 45 days, but may be extended by the contracting 
officer.
[50 FR 793, Jan. 7, 1985]



819.804  Agency evaluation of the Small Business Administration's request for a commitment.

    (a) The contracting officer will notify SBA in writing of the time 
limit for contract negotiations in accordance with FAR 19.804(b). The 
time limit, as a minimum, should be 45 days, but may be extended by the 
contracting officer.
[50 FR 793, Jan. 7, 1985]



819.806-2  Estimating the current fair market price.

    (a) Estimating the fair market price is a crucial initial step in 
determining what is a reasonable price for a negotiated 8(a) contract. 
For supplies and equipment, previous prices paid under

[[Page 189]]

competitive conditions, adjusted for inflation, may provide necessary 
data to make such an estimate.
    (b) Estimating fair market price for such services as architect-
engineer and construction may be accomplished through independent cost 
estimates and other pertinent data obtained from SBA when the estimated 
fair market price is not fully supportable from available documentation 
(see FAR 19.806-2(a)).
[52 FR 37317, Oct. 6, 1987]



819.806-3  Pricing review by the Small Business Administration.

    In order to expedite the 8(a) process, SBA should be informed as 
soon as a disparity between the 8(a) offered price and the estimated 
fair market price is determined. The SBA and the VA contracting office 
should collaborate to determine if the disparity is:
    (a) A result of deficiencies in developing the fair market price, 
thereby requiring revision to the estimate;
    (b) A result of overpricing by the 8(a) company, thereby requiring 
further efforts to negotiate a decrease in the offered price; or
    (c) A legitimate differential which should be funded through the SBA 
business development expense.
[52 FR 37317, Oct. 6, 1987]



819.806-4  Funding business development expense.

    If SBA declines to fund the business development expense, it will be 
reported in accordance with 819.870.
[52 FR 37317, Oct. 6, 1987]



819.807-70  Commitments of the Office of Facilities' funded projects for the 8(a) program.

    Major and minor projects funded by the Office of Facilities 
(including those delegated to the Veterans Health Services and Research 
Administration) which have been committed to the 8(a) program will not 
be withdrawn from that program without the consent of the Office of 
Small and Disadvantaged Business Utilization (005SB). Requests for 
consent from 005SB will normally be in writing and will clearly set 
forth the circumstances necessitating 8(a) withdrawal. If the 
contracting officer determines that time does not permit a written 
request, an oral request will be made. Such an oral request will be 
confirmed in writing.
[49 FR 12608, Mar. 29, 1984, as amended at 52 FR 46083, Dec. 4, 1987; 54 
FR 40064, Sept. 29, 1989]



819.809-70  Procurement of supplies, services, and research and development.

    (a) Contracts for supplies, equipment and services other than 
construction will be prepared as any other prime contract and in 
accordance with FAR Subpart 19.8.
    (b) The Department of Veterans Affairs contracting officer will 
forward the prime contract to SBA in sufficient numbers to furnish two 
copies to SBA and one copy to each subcontractor. SBA will return the 
signed original to the Department of Veterans Affairs contracting 
officer.



819.809-71  Procurement of construction.

    Construction projects which have been selected for inclusion in this 
program will be contracted for as provided in this section and FAR 
Subpart 19.8.
    (a) The contracting officer will submit, for each project so 
identified, the complete project listing including technical 
specifications, drawings and wage rates to the proper official of the 
appropriate SBA regional office. Should SBA select a competent 
subcontractor capable of performing the work, they will so certify to 
the Department of Veterans Affairs contracting officer. They will 
furnish him/her the name and complete address of the subcontractor(s), 
the project involved and the price(s) quoted. If the price quoted is 
within the range acceptable to the Department of Veterans Affairs, the 
contracting officer will indicate acceptance to SBA.
    (b) When the contracting officer receives Standard Form 1442, 
Solicitation, Offer and Award (Construction, Alteration, or Repair), 
signed by SBA and the subcontractor, and the performance and payment 
bonds, the contracting officer will forward a notice to proceed to the 
subcontractor.

[[Page 190]]



       Subpart 819.70--Veteran-Owned and Operated Small Businesses

    Source:  50 FR 793, Jan. 7, 1985, unless otherwise noted.



819.7001  Policy.

    (a) Pub. L. 93-237 amended the Small Business Act by directing SBA 
to give ``special consideration'' to veterans of the Armed Forces in all 
SBA programs. Consistent with and in furtherance of that statute, it is 
the policy of the Department of Veterans Affairs to encourage 
participation by veteran-owned and operated small businesses, including 
Vietnam era and disabled, in VA acquisitions.
    (b) All VA facilities having procurement requirements for which 
veteran-owned small businesses are known sources, will take affirmative 
action to solicit these firms and assist them in participating in VA 
acquisition opportunities.
[50 FR 793, Jan. 7, 1985, as amended at 55 FR 49900, Dec. 3, 1990]



819.7002  Definition.

    A veteran-owned small business is a small business that is at least 
51 percent owned by a veteran who also controls and operates the 
business. Control in this context means exercising the power to make 
policy decisions. Operate in this context means actively involved in 
day-to-day management. For purposes of this definition, eligible 
veterans include:
    (a) Veterans who served in the U.S. Armed Forces and were discharged 
or released under conditions other than dishonorable.
    (b) Vietnam era veterans who served for a period of more than 180 
days, any part of which was between August 5, 1964, and May 7, 1975, and 
were discharged other than dishonorably.
    (c) Disabled veterans with a minimum compensable disability of 30 
percent, or a veteran who was discharged for disability.
[49 FR 12608, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989; 
55 FR 49900, Dec. 3, 1990]



819.7003  Procedure.

    (a) To obtain information on business development for veteran-owned 
businesses and further identify veteran-owned small businesses, 
contracting officers shall contact the veterans affairs officers at the 
local SBA district office. When counselling small businesses, 
contracting officers shall determine if the business is veteran-owned 
and operated and ensure that SF 129s are completed properly to identify 
veteran-owned business.
    (b) The veteran-owned business representation in 852.219-70 shall be 
included in all solicitations.
[55 FR 49901, Dec. 3, 1990]



819.7004  Waiver of the use of veteran-owned firms.

    It is the policy of the Department of Veterans Affairs to provide 
veteran-owned firms every opportunity to participate in the acquisition 
process. A contracting office wishing to waive this policy for a 
particular procurement involving other than small purchase procedures 
must first process a VA Form 90-2268. The contracting officer must 
clearly document on VAF 90-2268 the reasons that eligible veteran-owned 
firms are not intended to be solicited or quotations sought for the 
particular procurement. Exempt from this reporting requirement are SBA 
8(a) acquisitions and Labor Surplus Area set-asides.
[50 FR 793, Jan. 7, 1985, as amended at 52 FR 37317, Oct. 6, 1987; 52 FR 
46083, Dec. 4, 1987; 54 FR 40064, Sept. 29, 1989; 55 FR 49901, Dec. 3, 
1990]



PART 822--APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITIONS--Table of Contents




       Subpart 822.3--Contract Work Hours and Safety Standards Act

Sec.
822.304  Variations, tolerances, and exemptions.

   Subpart 822.4--Labor Standards for Contracts Involving Construction

822.478  Contract terminations.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

[[Page 191]]


    Source:  49 FR 12610, Mar. 29, 1984, unless otherwise noted.



       Subpart 822.3--Contract Work Hours and Safety Standards Act



822.304  Variations, tolerances, and exemptions.

    When a contract is entered into for nursing home care, the clause 
prescribed by FAR 22.305 will be modified to reflect the variation 
contained in 29 CFR 5.15(d)(3) as set forth in 852.222-70.



   Subpart 822.4--Labor Standards for Contracts Involving Construction



822.478  Contract terminations.

    (a) Prior to terminating any contract because of violations of the 
labor standards provisions of the contract, contracting officers, other 
than those in the Office of Facilities will, through the Deputy 
Assistant Secretary for Acquisition and Materiel Management, present the 
facts in detail to the General Counsel for review. The contracting 
officer will be advised by the Deputy Assistant Secretary for 
Acquisition and Materiel Management as to the recommended action to be 
taken.
    (b) Prior to terminating a contract managed by the Office of 
Facilities for labor standards violation, the contracting officer will, 
through the Deputy Assistant Secretary for Facilities, present the facts 
in detail to the General Counsel for review. The contracting officer 
will be advised by the Deputy Assistant Secretary for Facilities as to 
the recommended action.
    (c) If the contract is to be terminated, the Deputy Assistant 
Secretary for Acquisition and Materiel Management or the Deputy 
Assistant Secretary for Facilities will submit the reports required by 
29 CFR 5.7(d).
[49 FR 12610, Mar, 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



PART 824--PROTECTION OF PRIVACY AND FREEDOM OF INFORMATION--Table of Contents




             Subpart 824.1--Protection of Individual Privacy

Sec.
824.102  General.

                Subpart 824.2--Freedom of Information Act

824.202  Policy.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).



             Subpart 824.1--Protection of Individual Privacy



824.102  General.

    (a) The pertinent Department rules regarding the implementation of 
the Privacy Act of 1974 consist of 38 CFR 1.575 through 1.584.
[49 FR 12611, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



                Subpart 824.2--Freedom of Information Act



824.202  Policy.

    Department rules implementing the Freedom of Information Act are 
contained in 38 CFR 1.550 through 1.559.
[49 FR 12611, Mar. 29, 1984; as amended at 54 FR 40064, Sept. 29, 1989]



PART 825--FOREIGN ACQUISITION--Table of Contents




                Subpart 825.1--Buy American Act--Supplies

Sec.
825.102  Policy.
825.102-70  Nonavailability in the United States.
825.105  Evaluating offers.
825.108  Excepted articles, materials and supplies.

         Subpart 825.2--Buy American Act--Construction Materials

825.202  Policy.

[[Page 192]]

825.202-70  Nonavailability in the United States.
825.203  Evaluating offers.

               Subpart 825.3--Balance of Payments Program

825.302  Policy.
825.302-70  Deviations from the Balance of Payments Program.
825.304  Excess and near-excess foreign currencies.
825.304-70  Determination of feasibility to use excess or near-excess 
          foreign currency.

                    Subpart 825.6--Customs and Duties

825.603  Procedures.
825.603-70  Technical assistance.

        Subpart 825.7--Restrictions on Certain Foreign Purchases

825.701  Policy.
825.703  Exceptions.

        Subpart 825.8--International Agreements and Coordination

825.870  Technical assistance.

      Subpart 825.9--Omission of the Examination of Records Clause

825.902  Policy.
825.904  Determination and findings.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12611, Mar. 29, 1984, unless otherwise noted.



                Subpart 825.1--Buy American Act--Supplies



825.102  Policy.



825.102-70  Nonavailability in the United States.

    (a) If articles, materials, and supplies required for a particular 
procurement are not excepted in FAR 25.108, or when only foreign bids or 
offers are received, the determination concerning nonavailability 
required by FAR 25.108(b) will be prepared by the contracting officer 
for foreign construction materials costing less than $1 million. Each 
determination will be factually supported in writing and included in the 
contract file.
    (b) Nonavailability determinations for foreign materials costing 
over $1 million must be requested by field facility contracting officers 
from the Deputy Assistant Secretary for Acquisition and Materiel 
Management (93). Each request for a determination must be fully 
justified with all pertinent facts.
    (c) A copy of all determinations made in accordance with paragraph 
(a) of this section shall be forwarded to the Deputy Assistant Secretary 
for Acquisition and Materiel Management (93) concurrently with the 
submissions required by FAR 25.108 (b) and (c).
[49 FR 12611, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 54 
FR 40064, Sept. 29, 1989]



825.105  Evaluating offers.

    When a determination is required under FAR 25.105, the contracting 
officer will submit the proposed award to the Deputy Assistant Secretary 
for Acquisition and Materiel Management (93) for approval by the 
Secretary. The submission will contain all the facts, including a 
comparison of all the bids or offers received, and any other pertinent 
information upon which a determination may be made. If approved, a 
report of the transaction will be prepared and submitted by the Deputy 
Assistant Secretary for Acquisition and Materiel Management in 
accordance with Executive Order 10582, dated December 17, 1954, as 
amended.



825.108  Excepted articles, materials and supplies.

    The following items are added to the list of exceptions contained in 
FAR 25.108(d):

Glass, Wire
Glass, Lead
Insulin, Human.
[52 FR 32012, Aug. 25, 1987]



         Subpart 825.2--Buy American Act--Construction Materials



825.202  Policy.



825.202-70  Nonavailability in the United States.

    (a) If articles, materials, and supplies required for a particular 
procurement are not excepted in FAR 25.108, or when only foreign bids or 
offers are received,

[[Page 193]]

the determination concerning nonavailability required by FAR 
25.202(a)(3) will be made by the contracting officer for foreign 
construction material costing $100,000 or less. Each determination will 
be factually supported in writing and included in the contract file.
    (b) Field facility contracting officers must request approval of 
nonavailability determinations from the Deputy Assistant Secretary for 
Acquisition and Materiel Management (93).
    (c) A copy of all determinations made in accordance with paragraph 
(a) of this section shall be forwarded to the Deputy Assistant Secretary 
for Facilities (08) through the Deputy Assistant Secretary for 
Acquisition and Materiel Management (93).
    (d) Each solicitation will include the clause specified in 852.236-
89. This provision reflects the general policy of not authorizing 
nondomestic materials on VA construction contracts.
[49 FR 12611, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 52 
FR 32012, Aug. 25, 1987; 54 FR 40064, Sept. 29, 1989]



825.203  Evaluating offers.

    When a contracting officer believes that the requirement of the 
``Buy American Act'' is impracticable as provided in FAR 25.202(a)(2), 
or that it would be advantageous to VA to deviate from the provisions of 
the Act as authorized by FAR 25.203, authority to consummate the 
contract will be requested. The request containing all the facts, 
including a comparison of all the bids or offers received and any other 
pertinent information upon which a determination may be made, will be 
submitted through the Deputy Assistant Secretary for Acquisition and 
Materiel Management (93), for approval by the Secretary. If approved, a 
report of the transaction will be prepared and transmitted by the Deputy 
Assistant Secretary for Facilities in accordance with Executive Order 
10582, dated December 17, 1954, as amended.
[49 FR 12611, Mar. 29, 1984, as amended at 52 FR 32012, Aug. 25, 1987; 
54 FR 40064, Sept. 29, 1989]



               Subpart 825.3--Balance of Payments Program



825.302  Policy.



825.302-70  Deviations from the Balance of Payments Program.

    When a contracting officer believes that the requirement of the 
``Balance of Payments Program'' is not practicable as set forth in FAR 
25.302 (b)(2) or (b)(3), he/she will request authority to consummate the 
contract through the Deputy Assistant Secretary for Acquisition and 
Materiel Management (93) for approval. Each request must be fully 
justified, containing all pertinent facts.



825.304  Excess and near-excess foreign currencies.



825.304-70  Determination of feasibility to use excess or near-excess foreign currency.

    In accordance with FAR 25.304(c), contracting officers will submit 
requests for determination to utilize excess or near-excess foreign 
currencies to the Deputy Assistant Secretary for Acquisition and 
Materiel Management (93).



                    Subpart 825.6--Customs and Duties



825.603  Procedures.



825.603-70  Technical assistance.

    Should the regulations contained in FAR 25.6 be inadequate to meet 
particular needs of a contracting officer in clearing items through 
customs and/or obtaining Duty Free Entry of goods, the nearest Regional 
Office of the United States Customs Service should be contacted for 
technical assistance. These offices are located as follows:

Regional Commissioner, U.S. Customs Service, 100 Summer St., Boston, 
Massachusetts 02110
Regional Commissioner, U.S. Customs Service, 99 S.E. 5th St., Miami, 
Florida 33131
Regional Commissioner, U.S. Customs Service, 585 Felipe St., Houston, 
Texas 77057
Regional Commissioner, U.S. Customs Service, 6 World Trade Center, New 
York, New York 10048

[[Page 194]]

Regional Commissioner, U.S. Customs Service, 423 Canal St., New Orleans, 
Louisiana 70130
Regional Commissioner, U.S. Customs Service, 300 N. Los Angeles St., Los 
Angeles, California 90053
Regional Commissioner, U.S. Customs Service, 55 E. Monroe St., Chicago, 
Illinois 60603



        Subpart 825.7--Restrictions on Certain Foreign Purchases



825.701  Policy.



825.703  Exceptions.

    When felt to be in the best interest of the Government, the 
contracting officer may request exceptions to the requirements of FAR 
25.7 for purchases in excess of $10,000 from the Secretary through the 
Deputy Assistant Secretary for Acquisition and Materiel Management (93). 
Each such request must be fully justified, containing all pertinent 
facts.



        Subpart 825.8--International Agreements and Coordination



825.870  Technical assistance

    Contracting officers may obtain technical information or guidance on 
international agreements and treaties for procurements outside the 
United States by contacting the Director, VA Marketing Center.



      Subpart 825.9--Omission of the Examination of Records Clause



825.902  Policy.

    If the contracting officer determines that the ``Examination of 
Records Clause'' should be omitted after all reasonable efforts to 
include the clause have failed, and providing that omission of the 
clause is authorized in the instances cited in FAR 25.903, he/she may 
request, with appropriate documentation, a determination from the 
Secretary, through the Deputy Assistant Secretary for Acquisition and 
Materiel Management (93). The Secretary, should he/she concur in the 
contracting officer's determination that the clause should be omitted, 
will then forward an agency request for omission of the clause to the 
Comptroller General for a final determination as required by FAR 25-
903(a)(1), or submit the report required by FAR 25.903(b).
[49 FR 12611, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



825.904  Determination and findings.

    All determinations to omit the ``Examination of Records Clause'' 
will be supported by a determination and findings prepared by the 
contracting officer containing the information set forth in FAR 25.904. 
The completed determinations and findings will be made a part of the 
contract file. One copy of the determinations and findings will be 
forwarded to the Deputy Assistant Secretary for Acquisition and Materiel 
Management (93).

[[Page 195]]



             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS





PART 828--BONDS AND INSURANCE--Table of Contents




                          Subpart 828.1--Bonds

Sec.
828.101  Bid guarantees.
828.101-3  Contract clause.
828.101-70  Safekeeping and return of bid guarantee.
828.106-6  Furnishing information.

                        Subpart 828.3--Insurance

828.306  Insurance under fixed-price contracts.

              Subpart 828.70--Performance and Payment Bonds

828.7000  Bond premium adjustment.

  Subpart 828.71--Indemnification of Contractors, Medical Research or 
                          Development Contracts

828.7100  Scope of subpart.
828.7101  General.
828.7102  Extent of indemnification.
828.7103  Financial protection.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12612, Mar. 29, 1984, unless otherwise noted.



                          Subpart 828.1--Bonds



828.101  Bid guarantees.



828.101-3  Contract clause.

    Where a bid bond is required for supplies or services, the phrase 
``any cost of acquiring the work'' in paragraph (e) of the BID GUARANTEE 
clause in FAR 52.228-1 may be modified to refer to the cost of 
``supplies,'' ``services,'' etc.



828.101-70  Safekeeping and return of bid guarantee.

    (a) Certified checks or other negotiable security furnished as bid 
security with the three lowest acceptable bids will be retained in a 
safe. These will be returned by certified mail or in person upon 
presentation of proper receipt after contract and bonds have been signed 
and approved.
    (b) Certified checks or other negotiable security furnished in 
support of other than the three lowest acceptable bids should be 
returned promptly to the respective bidders by certified mail, or in 
person upon presentation of proper receipt.
    (c) Commercial bid bonds are not returned unless specifically 
requested by the bidders, and, even if requested by any of the three low 
bidders, are not returned until contract and bonds have been executed by 
the successful bidder, or all bids have been rejected.



828.106-6   Furnishing information.

    The head of the contracting activity as defined in 802.100 shall be 
the agency designee referenced in FAR 28.106-6(c) to furnish copies of 
payment bonds to requestors except for contracts awarded by the Office 
of Facilities. For those contracts, Office of Facilities contracting 
officers shall be the Department designee.
[54 FR 30045, July 18, 1989]



                        Subpart 828.3--Insurance



828.306  Insurance under fixed-price contracts.

    (a) Term contracts, or contracts of a continuing nature, for 
ambulance, automobile and aircraft service, will contain the provision 
in 852.237-71.
    (b) Exceptions. The provisions of this 828.306 do not apply to 
emergency or sporadic ambulance service authorized by VA Manual MP-1, 
part II, chapter 3; or other emergency or sporadic vehicle or aircraft 
services. Provided, That such service is not used solely for the purpose 
of avoiding entering into a continuing contract. Provided further, That 
such services will be obtained from firms known to carry insurance 
coverage in accordance with State or local requirements.



              Subpart 828.70--Performance and Payment Bonds



828.7000  Bond premium adjustment.

    When performance and payment bonds are required, the contract will

[[Page 196]]

contain the clause prescribed in 852.228-70.



  Subpart 828.71--Indemnification of Contractors, Medical Research or 
                          Development Contracts



828.7100  Scope of subpart.

    (a) This subpart sets forth the policies and procedures concerning 
indemnification of contractors performing contracts which involve a risk 
of an unusually hazardous nature, covering medical research or 
development as authorized by 38 U.S.C. 4101.
    (b) The authority to indemnify the contractor under this subpart 
does not create any rights to third parties which would not otherwise 
exist by law.
    (c) As used in this subpart the term ``contractor'' includes 
subcontractors of any tier under a contract containing an 
indemnification provision pursuant to 38 U.S.C. 4101(c)(3)(A).



828.7101  General.

    (a) The approval for the indemnification of contractors will be made 
by the Secretary of Veterans Affairs.
    (b) Contracting Officers shall submit requests for approval, 
together with all available information, to the Deputy Assistant 
Secretary for Acquisition and Materiel Management (93) for transmittal 
to the Secretary.
[49 FR 12612, Mar. 29, 1984, as amended at 54 FR 24173, June 6, 1989; 54 
FR 30044, July 18, 1989]



828.7102  Extent of indemnification.

    (a) Any contract for medical research or development authorized by 
38 U.S.C. 4101, the performance of which involves a risk of an unusually 
hazardous nature, may provide that the Government will indemnify the 
contractor against either or both of the following, but only to the 
extent that they arise out of the direct performance of the contract and 
to the extent not covered by the financial protection required under 
828.7103.
    (1) Liability (including reasonable expenses of litigation or 
settlement) to third persons, except liability under State or Federal 
Workmen's Compensation Acts to employees of the contractor employed at 
the site of and in connection with the contract for which 
indemnification is granted, for death, bodily injury, or loss of or 
damage to property, from a risk that the contract defines as unusually 
hazardous.
    (2) Loss of or damage to property of the contractor from a risk that 
the contract defines as unusually hazardous.
    (b) A contract that provides for indemnification in accordance with 
this subpart will also provide for:
    (1) Notice to the contracting officer of any claim or suit against 
the contractor for death, bodily injury, or loss of or damage to 
property; and
    (2) Control of or assistance in the defense by the Government, at 
its election, of such suit or claim for which indemnification is 
provided in the contract.



828.7103  Financial protection.

    (a) The financial protection to cover liability to third persons and 
loss of or damage to the contractor's property which the contractor is 
required to have and maintain shall be the maximum amount of insurance 
available from private sources; however, the Secretary may establish a 
lesser amount after taking into consideration the cost and terms of 
private insurance.
    (b) The financial protection may include private insurance, private 
contractual indemnities, self-insurance, other proof of financial 
responsibility, or a combination of such forms to provide the maximum 
amount required. When the contractor elects to utilize self insurance, 
proof of such financial responsibility up to the maximum amount required 
will be furnished the contracting officer prior to award.



PART 829--TAXES--Table of Contents




Sec.
829.000  Scope of part.

                         Subpart 829.1--General

829.101  Resolving tax problems.

                   Subpart 829.2--Federal Excise Taxes

829.202  General exemptions.

[[Page 197]]

829.202-70  Tax exemptions for alcohol products.
829.270  Tax exempt tobacco products for State institutions.
829.270-1  Institution responsibilities and procedures.
829.270-2  Processing of order by the Department of Veterans Affairs.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12614, Mar. 29, 1984, unless otherwise noted.



829.000  Scope of part.

    This part prescribes policies and procedures for exemptions from 
Federal excise taxes imposed on tobacco and alcohol products for such 
items purchased for use in the Department of Veterans Affairs medical 
care program and specifies refund procedures for State and local taxes.



                         Subpart 829.1--General



829.101  Resolving tax problems.

    Contracting officers will submit requests for legal advice through 
channels to the General Counsel.



                   Subpart 829.2--Federal Excise Taxes



829.202  General exemptions.



829.202-70  Tax exemptions for alcohol products.

    (a) General. (1) The procurement of spirits free of tax for 
nonbeverage purposes is permitted to Government agencies by regulations 
of the Bureau of Alcohol, Tobacco, and Firearms (ATF) (see 27 CFR 
211.231-237, 213.141-146 and 240.720-722). The use of tax-free alcohol, 
whiskey, beer, wine and denatured spirits for nonbeverage purposes shall 
include but not be limited to medicinal and scientific purposes and in 
the treatment of patients.
    (2) Authority is hereby delegated to the Director, Marketing Center, 
Hines, Illinois, and to the Chief, Acquisition and Materiel Management 
Service, Department of Veterans Affairs medical facilities to sign 
application permits on Bureau of Alcohol, Tobacco, and Firearms (ATF) 
prescribed forms. This authority is not to be redelegated.
    (b) Whiskey, alcohol, and denatured alcohol. (1) Application forms 
for tax-free purchases are to be obtained from and submitted to the 
Director, Bureau of Alcohol, Tobacco, and Firearms, Washington, DC 
20226.
    (2) ATF Form 1486, Specially Denatured Spirits for Use of United 
States, is the application/permit required for denatured spirits, and 
ATF Form 1444, Tax-Free Spirits for Use of United States, is required 
for distilled spirits (whiskey and alcohol). These are continuing 
permits to procure items tax free. Copies must be made available to the 
supplier in support of each procurement.
    (3) Purchases for excise tax-free whiskey and alcohol, not available 
through the depot can only be made from a distillery or a bonded 
premises. In accordance with 27 CFR 213.144, the vendor will also 
support each shipment with ATF 1473, Shipment and Receipt Specifically 
Denatured Tax-Free, or Recovered Spirits. The ATF 1473 will be completed 
by the accountable officer and the original copy will be forwarded to 
the Regional Regulatory Administrator whose address is shown in item 12 
of the form. A copy of ATF 1473 will be retained in the purchase order 
file.
    (c) Wine. No tax exemption form or ATF permit is required for the 
tax-free procurement of wine. An extra copy of a properly executed 
purchase order or requisition document may be furnished to the supplier 
(retailer, wholesaler or winery) to facilitate record keeping.
    (d) Beer. Tax-free beer may be procured only from licensed breweries 
and only when such product is prescribed for therapeutic use of 
patients. The application for an ATF permit is to be submitted in letter 
form to the Director, Bureau of Alcohol, Tobacco, and Firearms, 
Washington, DC 20226. The following information is required.
    (1) Name and address of facility;
    (2) Specific purpose for which beer will be used;
    (3) Quantity proposed to buy each month, year, etc.;
    (4) Name and address of brewery; and
    (5) Copy of document authorizing contracting officer to sign 
request.
    A new permit is needed only when beer is to be purchased from a 
different

[[Page 198]]

brewery than the one for which the original permit was requested.
[49 FR 12614, Mar. 29, 1984, as amended at 54 FR 24173, June 6, 1989]



829.270  Tax exempt tobacco products for State institutions.

    (a) Bureau of Alcohol, Tobacco, and Firearms regulations permit the 
withdrawal of tax-free tobacco products by facilities and institutions 
owned or controlled by State Governments, territories, and the District 
of Columbia for gratuitous distribution to present and former members of 
the Armed Forces of the United States who are patients in such 
institutions (27 CFR 295.31-37). These arrangements will be effective 
only with institutions where the official-in-charge abides by the 
procedures and controls prescribed by the Department of Veterans 
Affairs. The unauthorized or illegal use of these products may result in 
the withdrawal of this privilege by the Department of Veterans Affairs.
    (b) No tax exemption form or certificate is required for the tax-
free purchase of tobacco products. An extra copy of the purchase order 
will be provided the manufacturer to facilitate record keeping required 
by the Bureau of Alcohol, Tobacco, and Firearms.



829.270-1  Institution responsibilities and procedures.

    (a) The official-in-charge of the institution will act as a 
representative of the Department of Veterans Affairs in the purchase, 
storage, and distribution of these products and in ensuring the product 
is distributed on a gratuitous and equitable basis to all eligible 
recipients. Under no circumstances will these items be offered for sale.
    (b) The Department of Veterans Affairs will neither accept nor 
handle donations or funds for institutions.
    (c) Payment or nonpayment of State taxes on tobacco products is a 
matter between the concerned State and the ordering institution.
    (d) Orders will be on the institution's regular order form made out 
to the manufacturer of the desired product. The original and two copies 
of the order, each signed, will be forwarded to the nearest Department 
of Veterans Affairs medical center. Orders shall also be issued to cover 
receipt of unsolicited shipments of these products intended for use of 
veteran-patients. All copies of these orders will be marked 
CONFIRMATION--DO NOT RESHIP. All orders shall bear a certificate as 
follows:

    Tobacco products for free distribution to present and former members 
of the Armed Forces of the United States who are hospitalized or 
domiciled in this institution.

    (e) Copies of all orders and other pertinent documents will be 
retained and be available to the Department of Veterans Affairs and the 
Bureau of Alcohol, Tobacco, and Firearms for inspection purposes.



829.270-2  Processing of order by the Department of Veterans Affairs.

    (a) Full cooperation will be given institution representatives in 
implementing these procedures.
    (b) The facility director or designee will approve the institution 
order by signing the original and one copy in ink over his/her printed 
name and title. The approved orginal and copy shall be forwarded to the 
vendor as noted in 829.270. The additional copy shall be retained in the 
medical center's files.
[49 FR 12614, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 54 
FR 40064, Sept. 29, 1989]



PART 831--CONTRACT COST PRINCIPLES AND PROCEDURES--Table of Contents




         Subpart 831.70--Contract Cost Principles and Procedures

Sec.
831.7000  Scope of subpart.
831.7001  Allowable costs under cost reimbursement vocational 
          rehabilitation and education contracts or agreements.
831.7001-1  Tuition.
831.7001-2  Special services or courses.
831.7001-3  Books, supplies and equipment required to be personally 
          owned.
831.7001-4  Medical services and hospital care.
831.7001-5  Secretary's Decision No. 557.
831.7001-6  Consumable instructional supplies.
831.7001-7  Reimbursement for other supplies and services.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

[[Page 199]]


    Source:  49 FR 12615, Mar. 29, 1984, unless otherwise noted.



         Subpart 831.70--Contract Cost Principles and Procedures



831.7000  Scope of subpart.

    This subpart contains general cost principles and procedures for the 
determination and allowance of costs in connection with the negotiation 
and administration of cost reimbursement type contracts pertaining to 
the furnishing of vocational rehabilitation, education, and training to 
eligible veterans under chapter 31 of Title 38, United States Code.



831.7001  Allowable costs under cost reimbursement vocational rehabilitation and education contracts or agreements.



831.7001-1  Tuition.

    (a) Except as provided in this section, when the contractor has a 
customary cost of tuition the charge to the Department of Veterans 
Affairs may not exceed that charged to similarly circumstanced 
nonveteran students; provided that where the contractor has more than 
one standard charge for the same service, the charge to the Department 
of Veterans Affairs will be the lowest price for the entire course, 
semester, quarter, or term which is offered or published.
    (b) VA will not normally pay tuition or incidental fees to 
institutions or establishments furnishing apprentice or other training 
on-the-job. VA may pay:
    (1) For such charges customarily made by nonprofit workshop or 
similar establishment for providing work adjustment training to 
similarly circumstanced nonveterans even though an incentive wage is 
paid the trainee as part of the training; or
    (2) For certain training expenses incurred by an employer providing 
on-the-job training following rehabilitation to the point of 
employability when such additional training is determined to be 
necessary by VA.
    (c) When the total cost of instruction is paid from Federal funds or 
a portion of the cost is covered by grants from the Federal Government, 
i.e., Smith-Hughes or other laws, excluding Federal Land Grant Funds, 
such subsidy will be taken into consideration in determining the charge 
to the Department of Veterans Affairs. The term, Federal Land Grant 
Funds, refers to those received under the Morrill-Nelson Act (Morrill 
Acts of 1862 and 1890 and the Nelson amendment of 1907) and section 22 
of the Bankhead-Jones Act of 1935.
    (d) Payments on behalf of a veteran who receives a fellowship, 
scholarship, grant-in-aid, assistantship, or similar award in complete 
or partial payment of tuition or fees or both will be made in accordance 
with the following:
    (1) The award will reduce, to the extent of the award, the amount of 
tuition or fee or both that is payable by the Department of Veterans 
Affairs.
    (2) Awards which are not paid in cash, except those which are made 
specifically for the purpose of defraying the cost of room and board in 
dormitories which will be disregarded, will reduce to the extent of the 
award the charges for which the Department of Veterans Affairs is 
responsible.
    (3) Cash awards may be retained by the veterans and will not be 
deducted from charges ordinarily paid by the Department of Veterans 
Affairs.
    (4) Waivers of tuition and fees provided under law by States or 
other Government authority will be utilized to reduce the charges 
payable by Department of Veterans Affairs in accordance with such 
waivers.
    (e) Enrollment fees in an amount sufficient to cover the cost of 
registration may be paid, provided the institution or training 
establishment usually makes such a charge, and it does not exceed that 
charge made to other students or trainees.
[49 FR 12615, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



831.7001-2  Special services or courses.

    Special services or courses are those services requested by the 
Department of Veterans Affairs which are over and above those 
customarily required by the institution for similarly circumstanced 
nonveterans and are considered by the contracting officer to be 
necessary for the rehabilitation of the trainee. The costs of such 
special services or courses will be negotiated

[[Page 200]]

prior to being requested by the Department of Veterans Affairs.



831.7001-3  Books, supplies and equipment required to be personally owned.

    (a) Reimbursement for books, supplies, or equipment and referred to 
as supplies, will be made as provided in this section.
    (1) Reimbursement will be made for those supplies customarily 
required to be owned personally by all students taking the same course 
or courses except that reimbursement may be made for items which are not 
specifically required by the school for pursuit of the course, but are 
determined to be needed by VA because of the demands of the course, 
general possession by other students, and the disadvantage imposed on 
the veterans by not having the item. In no instance will the supplies be 
in a greater variety, quality, or amount than required of nonveteran 
students. In this instance required is in contradistinction to requested 
or desirable to have or necessary for a future profession or job but not 
required by the institution of all students in the course.
    (2) When supplies are available in several prices, grades, or 
qualities, reimbursement may be made only for such quality or grade that 
will meet the requirements.
    (3) Partial payment agreements in which the Department of Veterans 
Affairs shares payment with the veterans is not allowable.
    (4) The costs incurred by the institution in connection with the 
veteran's thesis such as typing, printing, microfilming, or otherwise 
reproducing the required number of copies; research expenses when 
certified by the veterans committee chairman, major professor, 
department head, or appropriate dean that such expenses are required in 
order to complete the course requiring the preparation of a thesis are 
considered as supplies and are authorized for reimbursement.
    (5) When the institution operates a bookstore or supply store for 
all students the reimbursement for supplies issued to trainees will be 
no greater than charges made to nonveteran students.
    (6) Where the institution, training establishment, or employer 
arranges for issuance of supplies to all students by stores or 
establishments not institutionally owned and to pay such store or 
establishment for supplies issued to trainees, reimbursement is 
allowable provided the charges are no greater than those paid by 
nonveterans or to the institutions whichever is the lesser.
    (7) Supplies purchased by the institution specifically for trainees 
will be reimbursed at the net cost to the institution.
    (8) Where the institution does not provide or arrange for issuance 
of generally required books, tools and supplies for students attending 
the facility, the institution, in cooperation with VA, may designate 
certain stores and establishments to provide generally required books, 
tools and supplies for veterans pursuing a vocational rehabilitation 
program. The vendor will be reimbursed in the same manner as for 
supplies provided or arranged for by the institutions.
    (9) Where it is customary in a survey subject to permit each student 
to obtain the aggregate of books for the subject on a rental basis 
(commonly referred to as a rental set) and the ownership or permanent 
possession by the student is not required, reimbursement is authorized 
for the rental charge provided it does not exceed the charge made to 
nonveteran students.
    (10) Educational and training institutions furnishing supplies to 
trainees which are required to be owned personally or on a rental basis 
by all students pursuing the same or similar course may be compensated 
for such services in an amount not exceeding 10 percent of the allowable 
charge for the supplies furnished or rented except:
    (i) Where the tuition covers the charges for supplies or rentals or 
a stipulated fee is assessed all students, handling charges are not 
allowable.
    (ii) The handling charge is not allowable for Government-owned books 
procured by the institution from the Library of Congress.
    (iii) In cases where an item of equipment will exceed $50 in cost, 
effort will be made to secure a lower handling charge than for those 
costing a lesser

[[Page 201]]

amount. The agreed percent for such handling charges will be included in 
the contract or added as an addendum.
[49 FR 12615, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



831.7001-4  Medical services and hospital care.

    (a) The VA may pay the customary student health fee when payment of 
the fee is required for similarly circumstanced nonveterans. If payment 
of the fee is not required for similarly circumstanced nonveterans 
payment, payment may be made if it is determined by the Veterans Health 
Services and Research Administration that such payment is in the best 
interest of the veteran and the government.
    (b) Where medical services or hospital care not covered by the 
customary students health fee are available in the school operated 
facilities or arrangements have been made by the institution with 
doctors and hospitals in the immediate area, reimbursement by the 
Veterans Benefits Administration for such services may be made in a 
contract for such services provided that the Director, VA Medical 
Center, determines:
    (1) That such arrangements are necessary to provide timely medical 
care for veterans attending the facility under provisions of Chapter 31; 
and
    (2) The general rates established for such services do not exceed 
the rates established by the Chief Medical Director.
    (c) VA may reimburse a rehabilitation facility for incidental 
medical services provided during a veteran's program at the facility.
[49 FR 12615, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



831.7001-5  Secretary's Decision No. 557.

    (a) Fees and expenses authorized under Secretary's Decision No. 557 
may be authorized for payment when the educational institution or 
training establishment makes such payments on behalf of the veteran.
    (b) Payment for fees and expenses not made by the educational 
institution or training establishment will be made in accordance with 
part 813 of this chapter or FAR 15-210(a)(1).



831.7001-6  Consumable instructional supplies.

    (a) Reimbursement for consumable instructional supplies which 
institutions require for the instruction of all students, veteran or 
nonveteran pursuing the same or comparable course or courses will be 
made when:
    (1) The supplies are entirely consumed in the fabrication of a 
required project.
    (2) The supplies are not consumed but are of such a nature that they 
cannot be salvaged from the end product for reuse for further 
instructions by disassembling or dismantling the end product.
    (b) Reimbursement for consumable instructional supplies is not 
allowable when:
    (1) The supplies can be salvaged for reuse.
    (2) The supplies used in a project which has been elected by the 
student as an alternate class project in order to produce an end product 
of greater value than that which is normally required to learn the 
skills of the occupation and which will become his property upon 
completion.
    (3) The supplies used in a project which has been selected by the 
institution to provide the student with a more elaborate end product 
than is required to provide adequate instruction as an inducement to the 
veteran to elect a particular course of study.
    (4) The salable value of the end product is equal to or greater than 
the cost of the supplies used in its fabrication or assembly and a 
reasonable use has not been made of such supplies so that they are not 
readily salvaged from the end product to be reused for instructional 
purposes.
    (5) The end product is of permanent value and retained by the 
institution.
    (6) A third party provides the articles or equipment for repair or 
improvement and for which he or she would otherwise pay a commercial 
price.
    (7) The number of projects resulting in end products in excess of 
the numbers normally required to teach the recognized job operations and 
processes of the occupation stipulated in the approved course of study.

[[Page 202]]

    (8) The cost of supplies are included in the charge for tuition or 
as a fee designated for such purpose.
[49 FR 12615, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



831.7001-7  Reimbursement for other supplies and services.

    Reimbursement shall be made for other services and assistance which 
may be authorized under provisions of applicable Chapter 31 regulations 
including but not limited to employment and self-employment, initial and 
extended evaluation, and independent living services.
[49 FR 12615, Mar. 29, 1984, as amended at 54 FR 40064, Sept. 29, 1989]



PART 832--CONTRACT FINANCING--Table of Contents




                     Subpart 832.4--Advance Payments

Sec.
832.402  General.
832.404  Exclusions.

             Subpart 832.5--Progress Payments Based on Costs

832.502  Preaward matters.
832.502-2  Contract finance office clearance.

                   Subpart 832.8--Assignment of Claims

832.805  Procedure.
832.805-70  Distribution/notification of assignment of claims.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12616, Mar. 29, 1984, unless otherwise noted.



                     Subpart 832.4--Advance Payments



832.402  General.

    The determination required by FAR 32.402(c)(1)(iii) will be made by 
the Deputy Assistant Secretary for Acquisition and Materiel Management. 
Prior to award, contracting officers will submit, through channels, the 
information required by FAR 32.409-1 for such determinations.



832.404  Exclusions.

    (a) Under the provisions of 31 U.S.C. 3324(d)(2), as amended, 
advance payment is authorized for subscriptions or other charges for 
newspapers, magazines, periodicals and other publications for official 
use of any office under the Government from appropriations available 
therefore, notwithstanding the provisions of 31 U.S.C. 3324(a). The term 
``other publications'' includes any publication printed, microfilmed, 
photocopied or magnetically or otherwise recorded for auditory or visual 
usage.
    (b) Under the provisions of 31 U.S.C. 1535, advance payment may be 
made for services and supplies obtained from another Government agency. 
This includes items such as coupons from the Government Printing Office 
and Operator Permits, Civilian Defense Radio System, and from the 
Federal Communications Commission.
    (c) Under the provisions of 5 U.S.C. 4109, advance payment may be 
made for all or any part of the necessary expenses for training 
Government employees in Government or non-Government facilities. This 
includes the purchase or rental of books, materials and supplies or 
services directly related to the training of a Government employee.



             Subpart 832.5--Progress Payments Based on Costs



832.502  Preaward matters.



832.502-2  Contract finance office clearance.

    Prior approval of actions listed in FAR 32.502-2 will be obtained 
from the Deputy Assistant Secretary for Acquisition and Materiel 
Management (93). Requests for approval shall be accompanied by full 
justification together with the recommendations of the contracting 
officer.



                   Subpart 832.8--Assignment of Claims



832.805  Procedure.



832.805-70  Distribution/notification of assignment of claims.

    (a) The Contracting officer will file the retained copy of the 
notice of assignment and the certified copy of the original instrument 
of assignment with

[[Page 203]]

the General Accounting Office copy of the contract.
    (b) Contracting officers will notify field facilities of any 
recognized assignment of payments under contracts executed in Central 
Office or by the Marketing Divisions in all cases where payment for 
articles and services under such contracts are certified and approved 
for payment in the field.
[49 FR 12616, Mar. 29, 1984, as amended at 54 FR 40065, Sept. 29, 1989]



PART 833--PROTESTS, DISPUTES, APPEALS--Table of Contents




                         Subpart 833.1--Protests

Sec.
833.102  General.
833.103  Protests to the Department.
833.104  Protests to GAO.
833.105  Protests to the GSBCA.
833.106  Solicitation provision.

                   Subpart 833.2--Disputes and Appeals

833.209  Suspected fraudulent claims.
833.211  Contracting officer's decision.
833.212  Contracting officer's duties upon appeal.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).



                         Subpart 833.1--Protests



833.102  General.

    Solicitations shall instruct interested parties (see 852.233-2) to 
deliver a copy of any protest filed with the General Accounting Office 
(GAO) or the GSA Board of Contract Appeals (GSBCA) to the contracting 
officer and the appropriate Central Office activity as follows:
    (a) For contracts to be awarded by the Office of Facilities 
Management: Chief Facilities Management Officer, Office of Facilities 
Management, Department of Veterans Affairs, 810 Vermont Avenue, NW., 
Washington, DC 20420.
    (b) For all other contracts: Deputy Assistant Secretary for 
Acquisition and Materiel Management (95B), Department of Veterans 
Affairs, 810 Vermont Avenue, NW., Washington, DC 20420.
[51 FR 23070, June 25, 1986, as amended at 52 FR 28559, July 31, 1987; 
54 FR 40065, Sept. 29, 1989; 58 FR 48974, Sept. 21, 1993; 61 FR 11586, 
Mar. 21, 1996]



833.103  Protests to the Department.

    (a) Filing of protests. (1) An interested party may protest to the 
contracting officer, the Deputy Assistant Secretary for Acquisition and 
Materiel Management, Acquisition Review Division, or the Chief 
Facilities Management Officer, Office of Facilities Management, as 
appropriate.
    (2) Protests must be in writing and addressed as follows:
    (i) Contracting officer protests--address where offer/bid is to be 
submitted;
    (ii) Deputy Assistant Secretary for Acquisition and Materiel 
Management, Acquisition Review Division, Department of Veterans Affairs, 
810 Vermont Avenue, NW., Washington, DC 20420; or
    (iii) Chief Facilities Management Officer, Office of Facilities 
Management, Department of Veterans Affairs, 810 Vermont Avenue, NW., 
Washington, DC 20420.
    (3) The protester shall furnish a copy of the protest, including 
relevant documents not issued by the contracting agency, to the 
individual or location designated by the contracting agency in the 
solicitation for receipt of protests. If there is no designation in the 
solicitation, the protester shall furnish a copy of the protest to the 
contracting officer.
    (4) No formal briefs or other technical forms of pleading or motion 
are required. Protest submissions should be concise, logically arranged 
and clearly state legally sufficient grounds of protest. An agency 
protest, however, may be dismissed for failure to comply with any of the 
requirements of this section.
    (5) Protests regarding certain issues may be dismissed by VA without 
consideration of the merits or forwarded to another agency for 
appropriate action. Among these protests are the following:
    (i) Contract administration. The administration of an existing 
contract is

[[Page 204]]

within the discretion of the contracting agency. Disputes between a 
contractor and the Department are resolved pursuant to the disputes 
clause of the contract and the Contract Disputes Act of 1978. 41 U.S.C. 
601-613.
    (ii) Small business size standards and standard industrial 
classification. Challenges of established size standards or the size 
status of particular firms, and challenges of the selected standard 
industrial classification are for review solely by the Small Business 
Administration. 15 U.S.C. 637(b)(6); 13 CFR 121.3-6 (1984).
    (iii) Small business certificate of competency program. Any referral 
made to the Small Business Administration pursuant to section 8(b)(7) of 
the Small Business Act, or any issuance of a certificate of competency 
or refusal to issue a certificate under such section is not reviewed in 
accordance with bid protest procedures absent a showing of possible 
fraud or bad faith on the part of Government officials.
    (iv) Protests under section 8(a) of the Small Business Act. Since 
contracts are let under section 8(a) of the Small Business Act to the 
Small Business Administration at the contracting officer's discretion 
and on such terms as agreed upon by the procuring agency and the Small 
Business Administration, the decision to place or not to place a 
procurement under the 8(a) subcontract are not subject to review absent 
a showing of possible fraud or bad faith on the part of Government 
officials or that regulations may have been violated. 15 U.S.C. 637(a).
    (v) Affirmative determination of responsibility by the Contracting 
Officer. Because a determination that a bidder or offeror is capable of 
performing a contract is based in large measure on subjective judgments 
which generally are not readily susceptible to reasoned review, an 
affirmative determination of responsibility will not be reviewed, absent 
a showing that such determination was made fraudulently or in bad faith 
or that definitive responsibility criteria in the solicitation were not 
met.
    (vi) Procurement protested to the General Services Administration 
Board of Contract Appeals. Interested parties may protest a procurement 
or proposed procurement of automated data processing equipment and 
services to the General Services Administration Board of Contract 
Appeals. After a particular procurement or proposed procurement is 
protested to the Board, the procurement may not, while the protest is 
before the Board, be the subject of a protest to the contracting agency. 
An interested party who has filed a protest with the Board may not 
protest the same matter to the contracting agency. 40 U.S.C. 759(h), as 
amended by section 2713 of the Competition in Contracting Act of 1984, 
Pub. L. 98-369.
    (vii) Walsh-Healey Public Contract Act. Challenges of the legal 
status of a firm as a regular dealer or manufacturer within the meaning 
of the Walsh-Healey Act is for determination solely by the procuring 
agency, the Small Business administration (if a small business is 
involved) and the Secretary of Labor. 41 U.S.C. 35-45.
    (viii) Subcontractor protests. The contracting agency will not 
consider subcontractor protests except where the subcontract is by or 
for the Government.
    (ix) Judicial proceedings. The contracting agency will not consider 
protests where the matter involved is the subject of litigation before a 
court of competent jurisdiction.
    (b) Answering protests. (1) On protests filed with the contracting 
officer, the contracting officer may make the determination identified 
in FAR 33.103(a). On protests filed with the Deputy Assistant Secretary 
for Acquisition and Materiel Management, Acquisition Review Division, or 
the Chief Facilities Management Officer, Office of Facilities 
Management, those individuals are authorized to make the determination 
identified in FAR 33.103(a). These determinations made under (a) and (b) 
of this section will be in writing and will be made part of the contract 
file.
    (2) The individuals identified in paragraph (c)(1) of this section 
will respond to any protests within 25 workdays after receipt of the 
protest. Preaward protests must be answered prior to contract award. Any 
delays in answering the protest will be communicated to all interested 
parties.
    (c) Letter to protester. When a protest has been lodged with the 
contracting

[[Page 205]]

officer and has been subsequently denied by the contracting officer, the 
letter to the protester along with copies to interested parties 
detailing the contracting officer's reasons for denying the protest will 
conclude with the following statement, naming the appropriate VA 
officials:

    Should you disagree with this decision, you may file an appeal with 
\1\____________. Any such appeal must be received within 14 calendar 
days after receipt of this letter. In the alternative, you may file an 
appeal with the General Accounting Office (GAO) at the following 
address: General Counsel, General Accounting Office, Washington, DC 
20548, ATTN: Procurement Law Control Group. Any GAO appeal must be filed 
within 14 calendar of this formal notification of or actual or 
constructive knowledge of initial adverse agency action (as determined 
in 4 CFR 21.0(e)). It should be noted that if you file an appeal with 
the Deputy Assistant Secretary for Acquisition and Materiel Management 
or the Chief Facilities Management Officer, Office of Facilities 
Management, you may waive your right of further appeal to the 
Comptroller General at a later date.
---------------------------------------------------------------------------

    \1\ The Deputy Assistant Secretary for Acquisition and Materiel 
Management, Acquisition Review Division, Department of Veterans Affairs, 
810 Vermont Avenue, NW, Washington, DC 20420 or (for contracts awarded 
by the Office of Facilities Management), Chief Facilities Management 
Officer, Office of Facilities Management, 811 Vermont Avenue, NW., 
Washington, DC 20420.
---------------------------------------------------------------------------

    (d) Requests for GAO advance decisions. When a written protest has 
been lodged with the contracting officer and he/she considers it 
desirable to do so, he/she may request an advance decision from the 
Comptroller General. The submission to the Comptroller General will be 
sent through the Deputy Assistant Secretary for Acquisition and Materiel 
Management, Acquisition Review Division or the Chief Facilities 
Management Officer, Office of Facilities Management, as appropriate, and 
will include the material indicated in FAR 33.104(a)(2). The contracting 
officer will notify the protesting individual or firm promptly in 
writing of the decision of the Comptroller General.
    (e) Protect after award. When written protect is lodged with the 
contracting officer, he/she will review the basis for award.
    (1) If the contracting officer determines that the award was proper, 
he/she will furnish the protester a written explanation of the basis for 
the award which is responsive to the allegations of the protest. The 
contracting officer will advise the protester that he/she may appeal the 
determination to the Deputy Assistant Secretary for Acquisition and 
Materiel Management, Acquisition Review Division, or the Chief 
Facilities Management Officer, Office of Facilities Management in the 
case of a Central Office architect-engineer or construction contract, or 
the Comptroller General as specified in paragraph (d) of this section.
    (2) If the contracting officer determines that the award is 
questionable, he/she will advise the contractor of the protest and 
invite him/her to submit his/her views and relevant information. At the 
same time, the contracting officer may seek to obtain a mutual agreement 
with the contractor to suspend performance on a no-cost basis or issue a 
stop-work order in accordance with contract clause, FAR 52.233-3, 
Protest After Award (July 1985). Whether or not the contractor agrees, 
the case will be submitted promptly to the Deputy Assistant Secretary 
for Acquisition and Materiel Management, Acquisition Review Division, or 
the Chief Facilities Management Officer, Office of Facilities 
Management, in the case of a Central Office architect-engineer or 
construction contract, who will either advise the contracting officer of 
the appropriate action to take, or submit the case to the Comptroller 
General for his/her decision.
[51 FR 23070, June 25, 1986, as amended at 52 FR 28560, July 31, 1987; 
52 FR 49017, Dec. 29, 1987; 54 FR 40065, Sept. 29, 1989; 58 FR 48974, 
Sept. 21, 1993; 61 FR 11586, Mar. 21, 1996; 61 FR 20492, May 7, 1996]



833.104  Protests to GAO.

    (a) General. (1) When a protest before or after award has been 
lodged with the General Accounting Office (GAO), the contracting officer 
will prepare a report to be forwarded to the Deputy Assistant Secretary 
for Acquisition and Materiel Management, Acquisition Review Division, or 
the Chief Facilities Management Officer, Office of Facilities 
Management, as appropriate, within 5 workdays after receipt of verbal 
notice of the protest or receipt of a

[[Page 206]]

copy of the protest, whichever occurs first, for preparation of the 
Department report. The report should include a copy of the documentation 
indicated in FAR 33.104(a)(2).
    (2) Contracting officers are responsible for the notification 
procedures outlined in FAR 33.104(a)(3).
    (b) Protests before award. When the Department has received notice 
from the GAO of a preaward protest filed directly with GAO, award shall 
not be made until the matter is resolved, unless the Deputy Assistant 
Secretary for Acquisition and Materiel Management, Acquisition Review 
Division, or the Chief Facilities Management Officer, Office of 
Facilities Management, as appropriate, approves the head of contracting 
activity findings required by FAR 33.104(b)(1) and GAO has been notified 
pursuant to FAR 33.104(b)(2).
    (c) Protests after award. Protests after award shall be handled in a 
manner consistent with procedures identified for protests before award. 
Although persons involved or affected by the filing of a protest may be 
limited, at least the contractor shall be furnished the notice of the 
protest and its basis by the contracting officer. When VA receives from 
GAO, within ten calendar days after award, a notice of protest filed 
directly with GAO, and it is determined by the head of the contracting 
activity pursuant to FAR 33.104(c)(2) that contract performance should 
be authorized, the written findings will first be approved by the Deputy 
Assistant Secretary for Acquisition and Materiel Management, Acquisition 
Review Division (or the Chief Facilities Management Officer, Office of 
Facilities Management, as appropriate), and the GAO must be notified as 
required by FAR 33.104(c)(3).
[51 FR 23070, June 25, 1986, as amended at 52 FR 28560, July 31, 1987; 
54 FR 40065, Sept. 29, 1989; 58 FR 48974, Sept. 21, 1993; 61 FR 11586, 
Mar. 21, 1996]



833.105  Protests to the GSBCA.

    (a) Contracting officers are required to forward appropriate 
documentation to prepare the Department's protest file within 3 workdays 
after receipt of the notice of protest to the Deputy Assistant Secretary 
for Acquisition and Materiel Management (95B).
    (b) Contracting officers are responsible for the notification 
procedures outlined in FAR 33.105(a)(2)(i). Confirmation of this 
notification process will be forwarded to the Deputy Assistant Secretary 
for Acquisition and Materiel Management, Acquisition Review Division, or 
the Chief Facilities Management Officer, Office of Facilities 
Management, as appropriate, within three workdays after receipt of the 
protest in order to comply with FAR 33.105(a)(2)(ii).
[51 FR 23070, June 25, 1986, as amended at 52 FR 28559, July 31, 1987; 
54 FR 40065, Sept. 29, 1989; 58 FR 48974, Sept. 21, 1993; 61 FR 11586, 
Mar. 21, 1996]



833.106  Solicitation provision.

    The contracting officer shall insert the provision at 852.233-70, 
Protest Content, in solicitations other than small purchases.
[58 FR 48974, Sept. 21, 1993]



                   Subpart 833.2--Disputes and Appeals



833.209  Suspected fraudulent claims.

    Matters relating to suspected fraudulent claims will be referred to 
the Assistant Inspector General, Office of Investigations (51) for 
investigation and referral to the Department of Justice. No collection, 
recovery or other settlement action will be initiated while the matter 
is in the hands of the Department of Justice without first obtaining the 
concurrence of the U.S. Attorney concerned, through the Inspector 
General.
[51 FR 23070, June 25, 1986]



833.211  Contracting officer's decision.

    (a) When a dispute cannot be settled by agreement and a final 
decision under the Disputes clause of the contract is necessary, the 
contracting officer shall furnish the contractor his/her final decision 
in the matter.
    (b) The decision must be identified as a final decision, be in 
writing, and include a statement of facts in sufficient detail to enable 
the contractor to fully understand the decision and the basis on which 
it was made. It will normally be in the form of a statement of the

[[Page 207]]

claim or other description of the dispute with necessary references to 
the pertinent contract provisions. It will set forth those facts 
relevant to the dispute, with which the contractor and the contracting 
officer are in agreement, and as clearly as possible, the area of 
disagreement.
    (c) Except as provided in paragraph (d) of this section, the 
decision shall, in addition to the material required by FAR 
33.211(a)(4), contain the following:

    The Department of Veterans Affairs Board of Contract Appeals (VABCA) 
is the authorized representative of the Secretary for hearing and 
determining such disputes. The rules of the VABCA are published in 
section 1.783, of Title 38, Code of Federal Regulations. The address of 
the Board is 810 Vermont Avenue, NW., Washington, DC 20420.
[51 FR 23070, June 25, 1986, as amended at 52 FR 28561, July 31, 1987; 
54 FR 40065, Sept. 29, 1989; 61 FR 20492, May 7, 1996]



833.212  Contracting officer's duties upon appeal.

    (a) When a notice of appeal in any form has been received by the 
contracting officer, that officer will endorse thereon the date of 
mailing (or date of receipt, if otherwise conveyed) and within 10 days, 
will forward said original notice of appeal and a copy of the 
contracting officer's final decision letter to the Department of 
Veterans Affairs Board of Contract Appeals (VABCA). Copies of the notice 
of appeal and the final decision letter will be transmitted concurrently 
to the Deputy Assistant Secretary for Acquisition and Materiel 
Management, Acquisition Review Division and the Assistant General 
Counsel (025). (In cases of construction contracts administered by the 
Office of Facilities Management, copies of appeal and final decision 
letter need not be transmitted to the Deputy Assistant Secretary for 
Acquisition and Materiel Management, Acquisition Review Division.)
    (b) Within 20 days of receipt of an appeal, or advice that an appeal 
has been filed, the contracting officer will assemble and transmit to 
the VABCA, through the Office of General Counsel (025), an appeal file 
consisting of all documents pertinent to the appeal, including:
    (1) The decision and findings of fact from which the appeal is 
taken;
    (2) The contract, including specifications and pertinent amendments, 
plans and drawings;
    (3) All correspondence between the parties pertinent to the appeal, 
including the letter or letters of claim in response to which the 
decision was issued;
    (4) Transcripts of any testimony taken during the course of 
proceedings and affidavits or statements of any witnesses on the matter 
in dispute made prior to the filing of the notice of appeal with the 
VABC; and
    (5) Any additional information considered pertinent.
[51 FR 23070, June 25, 1986; 51 FR 44179, Dec. 8, 1986; 61 FR 11586, 
Mar. 21, 1996]

[[Page 208]]



             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING





PART 836--CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS--Table of Contents




     Subpart 836.2--Special Aspects of Contracting for Construction

Sec.
836.202  Specifications.
836.204  Disclosure of the magnitude of construction projects.
836.206  Liquidated damages.
836.208  Concurrent performance of firm fixed-price and other types of 
          construction contracts.
836.209  Construction contracts with architect-engineer firms.
836.211  Distribution of advance notices and solicitations.

    Subpart 836.3--Special Aspects of Sealed Bidding in Construction 
                               Contracting

836.371  Notice to proceed.

                    Subpart 836.5--Contract Clauses.

836.513  Accident prevention.

               Subpart 836.6--Architect-Engineer Services

836.602  Selection of firms for achitect-engineer contracts.
836.602-1  Selection criteria.
836.602-2  Evaluation boards.
836.602-4  Selection authority.
836.602-5  Procedure for procurements estimated not to exceed the 
          Simplified Acquisition Threshold.
836.606-70  General.
836.606-71  Architect-engineer's proposal.
836.606-72  Contract price.
836.606-73  Application of 6-percent architect-engineer fee limitation.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12618, Mar. 29, 1984, unless otherwise noted.



     Subpart 836.2--Special Aspects of Contracting for Construction



836.202  Specifications.

    (a) The procedures described in part 810 shall be applicable to 
construction specifications.
    (b) The use of ``brand name or equal'' or other restrictive 
specifications by contract architect-engineers is specifically 
prohibited without the prior written approval of the contracting officer 
during the design stage. The contracting officer shall inform the 
prospective architect-engineers of this requirement during the 
negotiation phase, prior to award of contract for design.
    (c) If it is determined that only one product will meet the 
Government's minimum needs and VA will not allow the submission of 
``equal'' products, the bidders must be placed on notice that the 
``brand name or equal'' provisions of the ``Material and Workmanship'' 
clause found at FAR 52.236.5 and any other provision which may authorize 
the submission of an ``equal'' product, will not apply. In order to 
properly alert bidders to this requirement, the clause found at 852.236-
90, ``Restriction on Submission and Use of Equal Products,'' shall be 
included in the solicitation.
[52 FR 282, Jan. 5, 1987, as amended at 53 FR 7756, Mar. 10, 1988; 53 FR 
9631, Mar. 24, 1988; 54 FR 40065, Sept. 29, 1989; 61 FR 20492, May 7, 
1996]



836.204  Disclosure of the magnitude of construction projects.

    In lieu of the estimated price ranges described in FAR 36.204, the 
magnitude of VA projects should be identified in advance notices and 
solicitations in terms of one of the following price ranges:

    (a) Less than $25,000;
    (b) Between $25,000 and $100,000;
    (c) Between $100,000 and $250,000;
    (d) Between $250,000 and $500,000;
    (e) Between $500,000 and $1,000,000;
    (f) Between $1,000,000 and $2,000,000;
    (g) Between $2,000,000 and $5,000,000;
    (h) Between $5,000,000 and $10,000,000;
    (i) Between $10,000,000 and $20,000,000;
    (j) Between $20,000,000 and $50,000,000;
    (k) Between $50,000,000 and $100,000,000;
    (l) More than $100,000,000.

(This section has been promulgated as a deviation to the FAR as provided 
in FAR Subpart 1.4.)
[53 FR 1631, Jan. 21, 1988]



836.206  Liquidated damages.

    Liquidated damage provisions may be included in construction 
contracts

[[Page 209]]

when the criteria of 812.202 is met. If partial performance may be 
accepted and utilized to the advantage of the Government, the clause 
substantially as set forth in 852.212-70 will be included in addition to 
the clause set forth in FAR 52.212-5.



836.208  Concurrent performance of firm fixed-price and other types of construction contracts.

    When concurrent contracts of the type specified in FAR 36.208 are 
considered necessary or advantageous, prior approval will be requested 
of the Chief Medical Director for contracts involving Maintenance and 
Repair (M&R) funds or of the Chief Facilities Management Officer, Office 
of Facilities Management for contracts involving construction (major and 
minor) funds. Complete justification will be furnished in the request.
[49 FR 12618, Mar. 29, 1984, as amended at 54 FR 40065, Sept. 29, 1989; 
61 FR 11586, Mar. 21, 1996]



836.209  Construction contracts with architect-engineer firms.

    When it is considered necessary or advantageous to award a contract 
for construction of a project to a firm or person that designed the 
project, prior approval will be requested of the Chief Medical Director 
for contracts involving M&R funds or of the Chief Facilities Management 
Officer, Office of Facilities Management, for contracts involving 
construction funds. Complete justification will be furnished in the 
request.
[49 FR 12618, Mar. 29, 1984, as amended at 61 FR 11586, Mar. 21, 1996



836.211  Distribution of advance notices and solicitations.

    Distribution of specifications and drawings on Central Office 
projects will be in accordance with that established by the Project 
Director.
[49 FR 12618, Mar. 29, 1984, as amended at 61 FR 11586, Mar. 21, 1996; 
61 FR 20492, May 7, 1996]



    Subpart 836.3--Special Aspects of Sealed Bidding in Construction 
                               Contracting



836.371  Notice to proceed.

    (a) Construction contractors will be given a written ``Notice to 
Proceed'' with the work. A letter notice to proceed will normally be 
sent only after performance and payment bonds and the completed contract 
forms, where applicable, have been returned by the contractor and are 
accepted by the contracting officer. If the urgency of the work or other 
proper reason requires the contractor to begin work immediately, the 
award letter may include the ``Notice to Proceed'' with the reservation 
that payments are contingent upon receipt and approval of the required 
bonds.
    (b) If the contract provides for liquidated damages, the notice to 
proceed will be sent by certified mail, return receipt requested. It 
will advise the contractor that the work will be completed within ____ 
(insert contract time for completion)     calendar days from the date of 
receipt shown on the certified mail receipt card returned by the post 
office.
    (c) If the contract does not provide for liquidated damages, 
certified mail is not required. Notices to proceed for these contracts 
will establish a date for completion taking into consideration the time 
required for the notice to arrive by regular mail.
    (d) At the time the notice to proceed is sent to the contractor, a 
copy will be furnished to the resident engineer or the Chief, 
Engineering Service. A copy of the notice to proceed will be filed with 
copy A of the contract. When certified mail is used, the certified mail 
receipt card returned by the post office will be attached to the copy of 
the notice to proceed. Copies of the notice to proceed will be filed 
with copies C and D of the contract after the date of receipt has been 
established and indicated thereon.
[49 FR 12618, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 61 
FR 11587, Mar. 21, 1996; 61 FR 20492, May 7, 1996]

[[Page 210]]



                     Subpart 836.5--Contract Clauses



836.513  Accident prevention.

    The contracting officer shall insert the clause at 852.236-87, 
Accident Prevention, in all solicitations that contain the clause at FAR 
52.236-13, Accident prevention, or its Alternate.
[58 FR 48974, Sept. 21, 1993; 58 FR 58730, Nov. 3, 1993]



               Subpart 836.6--Architect-Engineer Services



836.602  Selection of firms for architect-engineer contracts.



836.602-1  Selection criteria.

    In addition to the evaluation criteria set forth in FAR 36.602-1, 
the board will consider the factors set forth in this section as they 
apply to the project or purpose of the selection. Values will be 
assigned to each factor in determining the relative qualifications of 
the firms identified as qualified through the preselection process. The 
values may be confirmed or adjustments may be made as a result of the 
discussions.
    (a) Reputation and standing of the firm and its principal officials 
with respect to professional performance, general management, and 
cooperativeness.
    (b) Record of significant claims against the client because of 
improper or incomplete architectural and engineering services.
    (c) Specific experience and qualifications of personnel proposed for 
assignment to the project, and record of working together as a team.
[49 FR 12618, Mar. 29, 1984, as amended at 61 FR 20493, May 7, 1996]



836.602-2  Evaluation boards.

    Central Office architect-engineer contractors will be selected by 
the board appointed by the Chief Facilities Management Officer, Office 
of Facilities Management. Field facility architect-engineer contractors 
will be selected by the board appointed by the facility director.
    (a) The evaluation board will be chaired by the Director of the 
Architect-Engineer Evaluation Staff, or the Area Project Manager (or 
Deputy Area Project Manager) will be designated to act when necessary. 
The board's members as appointed by the Chief Facilities Management 
Officer, Office of Facilities Management will include the appropriate 
Area Project Manager and as many qualified professional architects or 
engineers from the Office of Facilities Management technical services as 
may be considered appropriate for the particular project. Additional 
members from the Office of Facilities Management or from other VA 
administrations and staff offices will be designated for projects when 
appropriate.
    (b) The evaluation board for a VA field facility will consist of no 
less than two members, one of whom will be the Chief, Acquisition and 
Materiel Management Service, and the other the Chief, Engineering 
Service, or their alternates. Where a facility has two or more engineers 
on its staff, an additional engineer will be appointed to the board. The 
chairperson of the board will be the senior engineer.
[49 FR 12618, Mar. 29, 1984, as amended at 53 FR 1631, Jan. 21, 1988; 54 
FR 40065, Sept. 29, 1989; 61 FR 11587, Mar. 21, 1996]



836.602-4  Selection authority.

    The Chief Facilities Management Officer, Office of Facilities 
Management (for Central Office contracts) and the facility director (for 
field facility contracts), or persons acting in those capacities, are 
designated as the approving officials for the recommendations of the 
evaluation boards.
[49 FR 12618, Mar. 29, 1984, as amended at 53 FR 1631, Jan. 21, 1988; 61 
FR 11587, Mar. 21, 1996]



836.602-5  Procedure for procurements estimated not to exceed the Simplified Acquisition Threshold.

    Either of the procedures provided in FAR 36.602-5 may be used when 
authorized by the Chief Facilities Management Officer, Office of 
Facilities Management.
[49 FR 12618, Mar. 29, 1984, as amended at 53 FR 1631, Jan. 21, 1988; 61 
FR 11587, Mar. 21, 1996]



836.606-70  General.

    To assure that the fee limitation is not violated, the contracting 
officer will maintain suitable records to be

[[Page 211]]

able to isolate the amount in the total fee to which the 6-percent 
limitation applies.
[49 FR 12618, Mar. 29, 1984, as amended at 61 FR 20493, May 7, 1996]



836.606-71  Architect-engineer's proposal.

    The use of VA Form 08-6298, Architect-Engineer Fee Proposal, is 
mandatory for obtaining the proposal and supporting cost or pricing data 
from the contractor and subcontractor in the negotiation of all 
architect-engineer contracts for design services when the contract price 
is estimated to be $50,000 or over. In obtaining architect-engineer 
services for research study, seismic study, master planning study, 
construction management and other related services contracts, VA Form 
08-6298 shall also be used but supplemented or modified as needed for 
the particular project type.
[49 FR 12618, Mar. 29, 1984, as amended at 61 FR 20493, May 7, 1996]



836.606-72  Contract price.

    Where negotiations with the top-rated firm are unsuccessful, the 
contracting officer will terminate the negotiations and undertake 
negotiations with the firm next in order of preference after 
authorization by the Chief Facilities Management Officer, Office of 
Facilities Management or the facility director. Recommendation for award 
of the contract at the negotiated fee, will be submitted with a copy of 
the negotiation memorandum prepared in accordance with FAR 15.808 and, 
whenever a field pricing report has been received, to the Chief 
Facilities Management Officer, Office of Facilities Management, or the 
facility director, as appropriate.
[52 FR 282, Jan. 5, 1987, as amended at 54 FR 40065, Sept. 29, 1989; 61 
FR 11587, Mar. 21, 1996]



836.606-73  Application of 6-percent architect-engineer fee limitation.

    (a) The 6-percent fee limitation does not apply to the following 
architect or engineer services:
    (1) Investigative services including but not limited to:
    (i) Determination of program requirements including schematic or 
preliminary plans and estimates.
    (ii) Determination of feasibility of proposed project.
    (iii) Preparation of measured drawings of existing facility.
    (iv) Subsurface investigation.
    (v) Structural, electrical, and mechanical investigation of existing 
facility.
    (vi) Surveys: Topographic, boundary, utilities, etc.
    (2) Special consultant services not normally available in 
organizations of architects or engineers not specifically applied to the 
actual preparation of working drawings or specifications of the project 
for which the services are required.
    (3) Other:
    (i) Reproduction of approved designs through models, color 
renderings, photographs, or other presentation media.
    (ii) Travel and per diem allowances other than those required for 
the development and review of working drawings and specifications.
    (iii) Supervision or inspection of construction, review of shop 
drawings or samples and other services performed during the construction 
phase.
    (iv) All other services that are not integrally a part of the 
production and delivery of plans, designs, and specifications.
    (4) The cost of reproducing drawings and specifications for bidding 
and their distribution to prospective bidders and plan file rooms.
    (b) The total cost of the architect or engineer services contracted 
for may not exceed 6 percent of the estimated cost of the construction 
project plus the estimated cost of related services and activities such 
as those shown in paragraph (a) of this section. To support project 
submissions, VA Form 10-1193, Application for Health Care Facility 
Project, and VA Form 10-6238, EMIS Construction Program-Estimate 
Worksheet, will be used and the proposed technical services shown where 
necessary and applicable.
[49 FR 12618, Mar. 29, 1984, as amended at 61 FR 20493, May 7, 1996]

[[Page 212]]



PART 837--SERVICE CONTRACTING--Table of Contents




                Subpart 837.1--Service Contracts--General

Sec.
837.103  Contracting officer responsibility.
837.104  Personal services contracts.

                   Subpart 837.2--Consulting Services

837.203  Types of consulting services.
837.270  Special controls for letters of agreement.
837.271  Management and professional services.
837.271-1  Scope.
837.271-2  Definition.
837.271-3  Guidelines for use of contracts for management and 
          professional services.
837.271-4  Approval for use of contractual services.

   Subpart 837.3--Dismantling, Demolition, or Removal of Improvements

837.300  Scope of subpart.

             Subpart 837.4--Nonpersonal Health-Care Services

837.403  Contract clause.

                    Subpart 837.70--Mortuary Services

837.7001  General.
837.7002  List of qualified funeral directors.
837.7003  Funeral authorization.
837.7004  Administrative necessity.
837.7005  Unclaimed remains--all other cases.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12620, Mar. 29, 1984, unless otherwise noted.



                Subpart 837.1--Service Contracts--General



837.103  Contracting officer responsibility.

    When the contracting officer determines that legal assistance is 
necessary in determining whether a proposed service contract is for 
personal or nonpersonal services, he/she shall gather all the pertinent 
facts and request the opinion of District Counsel responsible for 
servicing the VA facility involved.



837.104  Personal services contracts.

    (a) Personal service contracts having an employer-employee 
relationship shall not be awarded but will be consummated in accordance 
with VA Manual MP-5, Parts I and II.
    (b) In addition to the elements used in assessing whether or not a 
contract is personal in nature identified in FAR 37.104(d), the 
following circumstances may also indicate a possible personal service 
contract.
    (1) The contract does not call for an end product which is 
adequately described in the contract.
    (2) The contract price or fee is based on the time actually worked 
rather than the results to be accomplished.
    (3) Office space, equipment and supplies for contract performance 
are to be furnished by the Department of Veterans Affairs.
    (4) Contractor personnel are to be used interchangeably with 
Department of Veterans Affairs personnel to perform the same function.
    (5) The Department of Veterans Affairs retains the right to control 
and direct the means and methods by which contractor personnel 
accomplish the work.
[49 FR 12620, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 61 
FR 20493, May 7, 1996]



                   Subpart 837.2--Consulting Services



837.203  Types of consulting services.

    For the purpose of this subpart the definition of consulting 
services shall, in addition to examples listed in FAR 37.203, include 
peer review of research proposals.



837.270  Special controls for letters of agreement.

    (a) Letters of agreement may be used to procure consulting services 
and advisory board memberships only by those individuals designated in 
801.670-14(a) and individuals delegated authority under the conditions 
specified in paragraph (b) of that section, and will be limited to a 
value of $500 per letter and to an accumulated annual total of $2,500 to 
any individual or firm. Letters of agreement should only be used where 
normal procurement channels

[[Page 213]]

are not feasible and only for obtaining the following services:
    (1) Consultant services including peer review of research proposals 
and advisory board memberships.
    (2) Management and professional services (837.271)
    (3) Instructors and training obtained pursuant to section 4122 of 
Title 38, United States Code.
    (b) The delegated official will perform or have performed for each 
letter of agreement all those duties and requirements prescribed in this 
subpart, as modified by paragraphs (c) and (d) of this section. That 
official will also insure that all reporting requirements are completed 
for each action.
    (c) The administration head or staff office director will be the 
highest level approving official for each procurement action which does 
not exceed $500 in consulting fees (excluding travel, per diem and other 
travel-related costs) and which does not award more than an accumulated 
total of $2,500 per year in consulting fees to any individual or firm. 
(Consulting services anticipated to exceed these dollar limitations will 
not be obtained through letters of agreement.)
    (d) In lieu of the requirements outlined in appendix A of this 
subpart 837.2, justifications for letters of agreement will provide a 
statement of need and will certify that such services do not 
unnecessarily duplicate any previously performed work or services. The 
justification will also certify that the procurement action will not 
violate post-employment restrictions prescribed in the Ethics in 
Government Act and 803.101-3.
    (e) All procurements for consulting services accomplished through 
letters of agreement will be entered into the agency consolidated 
listing of consultant contracts in the format prescribed by 837.205(d). 
All such log entries applicable to Central Office activities shall be 
forwarded to the Deputy Assistant Secretary for Acquisition and Materiel 
Management (93). The office shall also be responsible for entering such 
information pertaining to Central Office letters of agreement into the 
Federal Procurement Data System.
[49 FR 12620, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 54 
FR 40065, Sept. 29, 1989]



837.271  Management and professional services.



837.271-1  Scope.

    (a) The controls in this section are applicable to management and 
professional services, special studies and analyses and management and 
support services for research and development. Specific types of 
services to be controlled are listed in appendix B of this subpart. 
Management and support services for research and development are the 
same services listed in appendix B when procured with Research and 
Development funds. However, the controls do not apply to the conduct of 
research and development.
    (b) Services in other than the categories listed in appendix B are 
also controlled if covered by the definition in 837.271-2 and either 
represent unusual, nonroutine requirements or requirements having 
significant impact on Department operations. Contracting officers will 
be responsible for making such determinations.
    (c) This section does not apply to contracts for the medical, dental 
and ancillary care of beneficiaries or to contracts for the provision of 
other services directly to beneficiaries, such as educational services.
[49 FR 12620, Mar. 29, 1984, as amended at 54 FR 40065, Sept. 29, 1989]



837.271-2  Definition.

    The term management and professional services means those services 
related to the performance of operating functions of an agency, 
involving knowledge of an advanced type, and requiring the use of 
discretion and judgment. Management and professional services differ 
from consulting services in that the latter term refers to services of a 
purely advisory nature. Both categories of services involve selection of 
the contractor on the basis of qualifications, rather than price alone, 
and are therefore normally procured by negotiation.

[[Page 214]]



837.271-3  Guidelines for use of contracts for management and professional services.

    (a) Contracts are appropriate when:
    (1) Unusual or peak workloads occur that cannot be accomplished by 
Government personnel.
    (2) Work involved is of an intermittent, occasional, or one-time 
nature for which the hiring of Government personnel is not feasible.
    (3) They result in a more economical method of performing the work 
(see OMB Circular No. A-76, revised.)
    (b) Contracts are inappropriate (improper or illegal) when:
    (1) The service involves exercising a Governmental judgment; i.e., 
managing programs requiring value judgments; selection of priorities; 
direction of Federal employees; and all regulatory responsibilities.
    (2) An employer-employee relationship would be established or 
involved.
    (3) They circumvent personnel salary or ceiling limitations.
[49 FR 12620, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



837.271-4  Approval for use of contractual services.

    (a) All contracts controlled by this section require the approval of 
the Secretary except as provided in paragraph (b) of this section. The 
procedure to be used in obtaining approval is the same as that required 
for consulting service as prescribed in 837.205(c). The format and 
content of the supporting justification will be the same as that in 
appendix A of this subpart.
    (b) Contracts not exceeding $500 may be approved by the heads of 
facilities, without higher level review, for requirements emanating at 
the local level. In Central Office, contracts not exceeding $500 may be 
approved at one level above the requesting activity, without higher 
level review. Supporting justifications will be the same as required in 
paragraph (a) of this section.
    (c) The approvals of officials designated in paragraphs (a) and (b) 
of this section are in addition to and do not replace the technical and 
legal reviews of contract documents prior to award prescribed elsewhere 
in these regulations.
[49 FR 12620, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



   Subpart 837.3--Dismantling, Demolition, or Removal of Improvements



837.300  Scope of subpart.

    Contracting officers should be cognizant of the requirements 
contained in VA Manual MP-3, Part II, Chapter 6, for approval necessary 
prior to entering into a contract for disposal of VA real property. Such 
approval(s) shall be included in the contract file.



             Subpart 837.4--Nonpersonal Health-Care Services



837.403  Contract clause.

    The contracting officer shall insert the clause at 852.237-7, 
Indemnification and Medical Liability Insurance, in lieu of FAR Clause 
52.237-7, in solicitations and contracts for nonpersonal health-care 
services. The contracting officer may include the clause in bilateral 
purchase orders for nonpersonal health-care services awarded under the 
procedures in FAR part 13 and (VAAR) 48 CFR part 813.
[61 FR 52709, Oct. 8, 1996]



                    Subpart 837.70--Mortuary Services



837.7001  General.

    This subpart establishes the policies and procedures governing the 
procurement of funeral and burial services for deceased beneficiaries of 
the Department of Veterans Affairs, as provided in 38 U.S.C. 903.



837.7002  List of qualified funeral directors.

    Contracting officers will establish, in coordination with cognizant 
Medical Administration Service personnel, a list of funeral directors 
capable of performing the burial services specified in 837.7003. The 
contracting officer will attempt to establish a commitment to perform 
these services within the statutory limitation of $300. Each funeral 
director must be fully licensed in the

[[Page 215]]

jurisdiction in which the business operates. If there has been no prior 
experience with the funeral director which would ensure the adequacy of 
the funeral director's services and casket, arrangements will be made 
prior to contract negotiation to inspect the premises and the casket to 
be provided, and to check with the local business bureau and/or Chamber 
of Commerce.
[ 49 FR 12620, Mar. 29, 1984, as amended at 61 FR 20493, May 7, 1996]



837.7003  Funeral authorization.

    (a) When a veteran dies while receiving care in a Department of 
Veterans Affairs health care facility or in a non-Department of Veterans 
Affairs institution at Department of Veterans Affairs expense, and the 
decedent's remains are unclaimed, the Chief, Medical Administration 
Service, will forward to the Chief, Supply Service, a properly executed 
VA Form 10-2065, Funeral Arrangements, requesting that funeral and 
burial services for the deceased be procured. Burial will be made in the 
nearest National Cemetery having available grave space.
    (b) The contracting officer will enter into negotiations with local 
funeral directors to procure a complete funeral and burial service 
within the statutory allowance of $300. This service will consist of and 
will be specified on the purchase order, VA Form 90-2138, Order for 
Supplies or Services, as follows:
    (1) Preparation of the body, embalming.
    (2) Clothing.
    (3) Casket. (The casket, as a minimum, will be constructed from 
thick, strong particle board and must be of sufficient strength to 
support the weight of an adult human body. Cardboard or press paper or 
similar materials are not acceptable).
    (4) Securing all necessary permits.
    (5) Ensuring that a United States Flag (provided the funeral 
director in accordance with Veterans Health Services and Research 
Administration Manual M-1, Part I, paragraph 14.40) accompanies the 
casket to place of burial.
    (c) An additional allowance for transportation of the body to the 
place of burial is provided in 38 U.S.C. 903(a)(2). This allowance will 
cover the transportation cost of shipment of the body by common carrier 
or by hearse from the VA facility to the funeral home and to the place 
of burial, any charges for an outside (shipment) box, and the charges 
for securing all necessary permits for removal or shipment of the body. 
These costs are not chargeable against the $300 allowance.
    (d) In accordance with Veterans Health Services and Research 
Administration Manual M-1, Part I, paragraph 14.37, the contracting 
officer will designate the Chief, Medical Administration Service, or 
representative, to be responsible for the medical inspection of the 
mortuary services performed and inspection of the merchandise furnished. 
This designee will also be responsible for certifying receipt on the 
receiving report.
    (e) The Chief, Supply Services, will assist the Chief, Medical 
Administration Service, in developing the local procedures specified in 
Veterans Health Services and Research Administration Manual M-1, Part I, 
paragraph 14.37c.
[49 FR 12620, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 54 
FR 40065, Sept. 29, 1989]



837.7004  Administrative necessity.

    (a) When persons die under Department of Veterans Affairs care who 
are not legally entitled to such care at Department of Veterans Affairs 
expense, and no relatives or friends will claim the remains, and the 
municipal, county or State officials refuse to provide for final 
disposition, arrangements will be made and expenses assumed for burial 
locally under separate contractual agreement.
    (b) When a full and complete funeral and burial service as 
prescribed in 837.7003 cannot be obtained by the contracting officer 
within the statutory allowance, he/she will, prior to taking any further 
action, secure from the facility director a written determination that 
the disposition of the remains must be accomplished by the Department of 
Veterans Affairs as an administrative necessity. The facility director 
will also authorize in writing the expenditure of such additional funds 
as may be necessary for this purpose. The amount of these additional 
funds will be held to the minimum, keeping in

[[Page 216]]

mind, however, that the deceased must be given a proper and fitting 
interment.
    (c) The determination and authorization by the facility director 
will be made a part of the contract file.
[49 FR 12620, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 54 
FR 40065, Sept. 29, 1989]



837.7005  Unclaimed remains--all other cases.

    Requests for information on the disposition of the unclaimed remains 
of a veteran whose death occurs while not under the direct care or 
treatment of the Department of Veterans Affairs will be referred to the 
Veterans Services Officer for processing in accordance with Veterans 
Benefits Administration Manual M27-1, Part II. This manual is available 
at any Department of Veterans Affairs regional office, medical center or 
VA office.
[49 FR 12620, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]

[[Page 217]]



                    SUBCHAPTER G--CONTRACT MANAGEMENT





PART 842--CONTRACT ADMINISTRATION--Table of Contents




Sec.
842.000  Scope of part.
842.070  Definition.

  Subpart 842.1--Interagency Contract Administration and Audit Services

842.101  Policy.
842.102  Procedures.

          Subpart 842.2--Assignment of Contract Administration

842.202  Assignment of contract administration.

                   Subpart 842.7--Indirect Cost Rates

842.705  Final indirect cost rates.

                  Subpart 842.8--Disallowance of Costs

842.801-70  Audit assistance prior to disallowing costs.
842.803  Disallowing cost after incurrence.

         Subpart 842.12--Novation and Change-of-Name Agreements

842.1203  Processing agreements.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12624, Mar. 29, 1984, unless otherwise noted.



842.000  Scope of part.

    This part applies to all contracts, whether sealed bid or 
negotiated. (See 801.602-70 for requirements for legal review of certain 
contract administration actions.)
[49 FR 12624, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 51 
FR 23072, June 25, 1986; 52 FR 28559, July 31, 1987]



842.070  Definition.

    Contract Administration is the coordination of actions required for 
the performance of a contract including the guidance and supervision 
necessary to assure that all contractural obligations are fulfilled.



  Subpart 842.1--Interagency Contract Administration and Audit Services



842.101  Policy.

    (a) Pursuant to FAR policy encouraging interagency cross-servicing 
in field contract support services, contracting officers of the 
Department of Veterans Affairs will utilize the support services of 
other agencies to the extent feasible. Examples of such services are: 
preaward surveys; quality assurance and technical inspection of contract 
items; and review of contractors' procurement systems. Requirements for 
support services available from any other Government department or 
agency will be obtained on the basis of an approved negotiated 
interagency support agreement.
    (b) An interagency support agreement is a written instrument of 
understanding executed between the parties to the agreement. The 
agreement should state clearly the accord which has been reached between 
the two parties involved, especially the obligations assumed by the 
rights granted each. The agreement will be specific with respect to 
resources to be provided by both the supplying and receiving activities. 
It will also provide for funding and reimbursement arrangements, and 
clauses permitting revisions, modifications thereto, or cancellation 
thereof, will be included.



842.102  Procedures.

    (a) The Department of Defense Directory of Contract Administration 
Services Components and the Directory of Federal Contract Audit Offices 
are available through the Department of Veterans Affairs Forms and 
Publications Depot.
    (b) Proposed interagency support agreements with any other 
Government department or agency involving the expenditures of Department 
of Veterans Affairs funds of $5,000 of more will be forwarded by the 
facility director (or Central Office official) to the Deputy Assistant 
Secretary for Acquisition and Materiel Management (91),

[[Page 218]]

who will transmit with recommendation to the General Counsel for legal 
review and approval, as required by 801.602-70(a)(4).
    (1) Proposed agreements, both new and renewal, will be submitted in 
an original and four copies so as to reach Central Office 60 days prior 
to the effective date of the agreement.
    (2) Complete justification for all proposed agreements will be 
submitted, as approval depends on the adequacy of the justification.
[49 FR 12624, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



          Subpart 842.2--Assignment of Contract Administration



842.202  Assignment of contract administration.

    Proposed assignments of contract administration responsibility 
outside of the procuring activity will be forwarded by the facility 
director to the Deputy Assistant Secretary for Acquisition and Materiel 
Management (91), who will transmit the proposal to the General Counsel 
for legal review and approval, as required by 801.602-70(a)(6) and 
801.602-71. Complete justification will be provided, specifically 
addressing the need for and benefits to be provided by assignment of 
contract administration. (See 801.603-70 for policy on designating 
representatives of contracting officers, and FAR 30.401 for contracts 
involving Cost Accounting Standards.)
[49 FR 12624, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



                   Subpart 842.7--Indirect Cost Rates



842.705  Final indirect cost rates.

    (a) Contracting officers will request audits on proposed final 
indirect cost rates and billing rates for use in cost reimbursement, 
fixed price incentive and fixed price redeterminable contracts as 
described in FAR Subpart 42.7 unless the quick-closeout procedures 
described in FAR 42.708 are used. In this case, the contracting officers 
will perform a review and validation of the contractor's data submitted 
for accuracy and reasonableness of the proposed rates for negotiating 
the settlement of indirect costs for a specific contract.
    (b) Contracting officers in the Office of Acquisition and Materiel 
Management and Office of Facilities who are located in the VA Central 
Office have the option to request audits directly from the cognizant 
audit agencies or requesting audits through the Assistant Inspector 
General for Policy, Planning and Resources (53C). All other contracting 
officers located in the VA Central Office and the Office of the General 
Counsel will send requests for audit to the Assistant Inspector General 
for Policy, Planning and Resources (53C). Contracting officers located 
at field facilities, Marketing Center and supply depots are required to 
arrange for the audits through the Deputy Assistant Secretary for 
Acquisition and Materiel Management or the Deputy Assistant Secretary 
for Facilities. The Assistant Inspector General for Policy, Planning and 
Resources (53C) will provide such accounting assistance or technical 
advice as is deemed desirable by the contracting officers.
[49 FR 12624, Mar. 29, 1984, as amended at 52 FR 49017, Dec. 29, 1987; 
54 FR 40065, Sept. 29, 1989]



                  Subpart 842.8--Disallowance of Costs



842.801-70  Audit assistance prior to disallowing costs.

    When a contracting officer determines during the performance of a 
cost reimbursement, fixed price incentive or fixed price redetermination 
contract exceeding the thresholds specified in FAR 15.804-2, that costs 
should be disallowed, audit assistance will be requested. Such requests 
submitted by field facility contracting officers will be directed to the 
Deputy Assistant Secretary for Acquisition and Materiel Management (93) 
for review and forwarding to the Assistant Inspector General for 
Auditing (52), or other recognized audit agency, e.g., the Defense 
Contract Audit Agency.



842.803  Disallowing cost after incurrence.

    Contracting officers may approve contractors' vouchers for payment 
and

[[Page 219]]

process them to the servicing fiscal office. Such approval must be 
within the limitations of the contracting officer and the contract for 
which the voucher is submitted must be within the contracting officers 
delegation of contracting authority. (Note 842.801-70 regarding 
disallowing costs.)



         Subpart 842.12--Novation and Change-of-Name Agreements



842.1203  Processing agreements.

    Prior to execution of novation and change-of-name agreements by a 
Department of Veterans Affairs contracting officer, he/she will forward 
the agreement and related documents to the Office of General Counsel for 
review as to legal sufficiency. The documents will be submitted through 
the same channels as those prescribed for legal review of contracts in 
801.602-72.



PART 846--QUALITY ASSURANCE--Table of Contents




                     Subpart 846.3--Contract Clauses

Sec.
846.302-70  Inspection.

          Subpart 846.4--Government Contract Quality Assurance

846.408-70  Inspection of subsistence.
846.408-71  Waiver of USDA inspection and specifications.
846.470  Use of commercial organizations for inspections and grading 
          services.
846.471  Determination authority.
846.472  Inspection of repairs for properties under the Loan Guaranty 
          and Direct Loan Programs.
846.472-1  Repairs of $1,000 or less.
846.472-2  Repairs in excess of $1,000.

    Authority:  38 U.S.C. 501 and 40 U.S.C. 486(c).

    Source:  49 FR 12625, Mar. 29, 1984, unless otherwise noted.



                     Subpart 846.3--Contract Clauses



846.302-70  Inspection.

    Contracts for property will include the clause 852.210-72(a), 
``Rejected Goods,'' except that contracts for packinghouse, dairy 
products, bread and bakery products, and fresh and frozen fruits and 
vegetables will include the clause prescribed in 852.210-72(b), 
``Rejected Goods.''



          Subpart 846.4--Government Contract Quality Assurance



846.408-70  Inspection of subsistence.

    (a) The contracting officer will determine at the time of issuance 
of the solicitation whether inspection for specification compliance will 
be made: (1) Prior to shipment by representatives of the U.S. Department 
of Agriculture (USDA) or the Department of Commerce, or (2) at the time 
of delivery by personnel of the purchasing activity. The place of 
inspection will be indicated in the solicitation.
    (b) Since the requirement for USDA or Department of Commerce 
inspections and certifications results in additional contractor costs 
which may be ultimately reflected in bid prices, the contracting 
officer, in consultation with the Chief, Dietetics Service, must 
evaluate the need for such inspections. The evaluation shall include the 
following:
    (1) The quality assurance already provided by other mandatory 
inspection systems;
    (2) The proposed suppliers' own quality control system;
    (3) Experience with the proposed suppliers;
    (4) The feasibility of prequalifying suppliers' quality assurance 
systems and subsequently waiving certifications for future 
solicitations; and
    (5) The cost of the inspections.
    (c) When either the USDA or the Department of Commerce is indicated 
as the inspection activity, the solicitation will also provide that the 
contractor is responsible for:
    (1) Arranging and paying for inspection services.
    (2) Obtaining from the inspection activity a certificate indicating 
the product complies with specifications. Such certificate, or copy, 
should accompany the shipment or be furnished to the receiving 
installation prior to shipment. The contractor shall notify the 
installation when the certificate is not immediately available.
    (3) Seeing that acceptable products are covered by an inspection 
agency checkloading certificate or stamped by

[[Page 220]]

the inspector as prescribed by the contracting officer. Products not so 
identified shall be rejected.
    (4) Furnishing samples for inspection at his/her expense.
    (5) Indicating the address where inspection will be made.
    (d) The contracting officer will furnish a copy of the purchase 
document to the inspecting activity.
[49 FR 12625, Mar. 29, 1984, as amended at 51 FR 37027, Oct. 17, 1986; 
54 FR 40065, Sept. 29, 1989]



846.408-71  Waiver of USDA inspection and specifications.

    (a) Contracting officers may purchase butter; cheese (except cottage 
cheese); sausage; meat food products; \1\ bacon, smoked; and bacon, 
Canadian style, without reference to the specifications in Federal 
Hospital Subsistence Guide G-1, and the USDA inspection requirements, 
when the amount of an item to be purchased will not exceed 500 pounds 
per delivery. When these items are procured together with items that are 
not exempt, the solicitation shall include the following:
---------------------------------------------------------------------------

    \1\ Meat food products shall mean processed foods containing meat in 
substantial proportion and other listed ingredients including seasoning, 
e.g., frankfurters, coldcuts. Whole or prefabricated meats, e.g., pork 
chops, hamburger, are considered meats, not meat food products.

    Items * * * are not required to be in accordance with the 
specifications contained in Federal Hospital Subsistence Guide G-1, and 
the special USDA inspection is not required. Inspection for quality and 
condition will be made by VA upon delivery at destination. These items 
---------------------------------------------------------------------------
are, however, subject to the quality controls stated herein.

    (b) As appropriate, the following statements shall be included in 
each invitation for bid, request for proposal or purchase order:
    (1) Butter. This product must be graded by the USDA and labeled 
``Grade A'' or the grade specified herein.
    (2) Sausage and meat food products:
    (i) This product must be a high commercial product and shall have 
been prepared in a federally inspected plant and bear the USDA 
establishment number stamp which evidences that it is sound, healthful, 
wholesome and fit for human consumption; and
    (ii) This product must bear a label complying with the Federal Food, 
Drug and Cosmetic Act which requires that all ingredients be listed 
according to the order of their predominance.
    (3) Bacon, smoked; and bacon, Canadian style. This product must be a 
high commercial product and shall have been prepared in a federally 
inspected plant and bear the USDA establishment number stamp which 
evidences that it is sound, healthful, wholesome, and fit for human 
consumption.
    (c) When using a ``brand name or equal'' purchase description every 
brand name item that is known to be acceptable and available in the area 
will be listed.
[49 FR 12625, Mar. 29, 1984, as amended at 51 FR 37028, Oct. 17, 1986]



846.470  Use of commercial organizations for inspections and grading services.

    Commercial organizations may be used for inspection and grading 
services when it is determined that the results of a technical 
inspection or grading are dependent upon the application of scientific 
principles or specialized techniques, and it is further determined that:
    (a) The Department of Veterans Affairs is unable to employ the 
personnel qualified to properly perform the services and is unable to 
locate another Federal agency capable of providing the service.
    (b) The inspection or grading results issued by a private 
organization are essential to verify the acceptance or rejection of a 
special commodity.
    (c) The services may be performed without direct Government 
supervision.
[49 FR 12625, Mar. 29, 1984, as amended at 54 FR 40065, Sept. 29, 1989]



846.471  Determination authority.

    The determinations required in 846.470 will be made by:
    (a) The Director, Office of Construction, for those items and 
services for which purchase authority has been assigned to him/her.
    (b) The Director, Veterans Canteen Service, VHS&RA, for those items 
and

[[Page 221]]

services purchased, or contracted for, by the Veterans Canteen Service 
(except those items purchased from Department of Veterans Affairs supply 
sources).
    (c) The Deputy Assistant Secretary for Acquisition and Materiel 
Management for all other supplies, equipment and services.



846.472  Inspection of repairs for properties under the Loan Guaranty and Direct Loan Programs.

    Final inspection will be made of all repair programs upon 
completion. In addition such intermediate or progress inspections will 
be made on extensive or technical jobs as specified in the contract.



846.472-1  Repairs of $1,000 or less.

    (a) Generally, inspections required will be made by the management 
broker. If the property has not been assigned to a management broker or 
if it has been determined that the nature of the repairs requires 
supervision by a technician, the inspection will be made by a qualified 
fee or staff inspector.
    (b) There is no form prescribed for this inspection but VA Form 26-
1839, Compliance Inspection Report, may be used if desired. Regardless 
of the form in which the report is submitted, it will be in sufficient 
detail to identify the contractor, property, and the repair program and 
to enable the contracting officer to make a determination that the work 
is being performed satisfactorily or completed in accordance with the 
terms of the contract.



846.472-2  Repairs in excess of $1,000.

    (a) The final inspection and any intermediate or progress 
inspections on repairs exceeding $1,000 will be made by a qualified fee 
or staff inspector. If a management broker is qualified to supervise 
major repairs, he/she may be authorized to conduct the inspections.
    (b) Report of inspections will be made on VA Form 26-1839, 
Compliance Inspection Report. The form will be completed to identify the 
property, contractor, and repair program and will also include such 
detailed information to enable the contracting officer to make a 
determination that the work is being performed satisfactorily or that it 
has been completed in accordance with the contract terms. Any 
deficiencies noted will be itemized and explained in detail.



PART 847--TRANSPORTATION--Table of Contents




            Subpart 847.3--Transportation in Supply Contracts

847.303-1  F.o.b. origin.
847.303-70  F.o.b. origin, freight prepaid, transportation charges to be 
          included on the invoice.
847.304  Determination of delivery terms.
847.304-1  General.
847.305-70  Potential destinations known but quantities unknown.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12627, Mar. 29, 1984, unless otherwise noted.



            Subpart 847.3--Transportation in Supply Contracts



847.303-1  F.o.b. origin.

    (a) Normally shipments falling within this category will be shipped 
on a Government bill of lading, except for those shipments covered by 41 
CFR 101-41.304-2.
    (b) Shipment of flat bronze markers by the vendor, as directed by 
the Director, Monument Service, or his/her designee, will be made by 
parcel post. VA Form 40-4951, Order for Flat Bronze Marker, will be used 
for this purpose.



847.303-70  F.o.b. origin, freight prepaid, transportation charges to be included on the invoice.

    (a) The delivery terms will be stated as ``f.o.b. origin, 
transportation prepaid, with transportation charges to be included on 
the invoice,'' under each of the following circumstances:
    (1) When it has been carefully determined that an f.o.b. origin 
purchase or delivery order will have transportation charges not in 
excess of $100 and the occasional exception does not exceed that amount 
by an unreasonable amount;
    (2) Single parcel shipments via express, courier, small package, or 
similar carriers, regardless of shipping cost, if the parcel shipped 
weighs 70 pounds

[[Page 222]]

or less and does not exceed 108 inches in length and girth combined;
    (3) Multi-parcel shipments via express, courier small package, or 
similar carriers for which transportation charges do not exceed $250 per 
shipment.
    (b) Orders issued on VA Form 90-2138, Orders for Supplies or 
Services, will direct the vendor's attention to shipping instructions on 
the reverse of the form. When VA Form 90-2138 is not used, the vendor 
will be instructed as follows:
    (1) Consistent with the terms of the contract, pack, mark and 
prepare shipment in conformance with carrier requirements to protect the 
personal property and assure assessment of the lowest applicable 
transportation charge.
    (2) Add transportation charges as a separate item on your invoice. 
The invoice must bear the following certification: ``The invoiced 
transportation charges have been paid and evidence of such payment will 
be furnished upon the Government's request.''
    (3) Do not include charges for insurance or valuation on the invoice 
unless the order specifically requires that the shipment be insured or 
the value be declared.
    (4) Do not prepay transportation charges on this order if such 
charges are expected to exceed $100. Ship collect and annotate the 
commercial bill of lading, ``To be converted to Government Bill of 
Lading.''
    (c) Each contracting officer is responsible for:
    (1) Making a diligent effort to obtain the most accurate estimate 
possible of transportation charges; and
    (2) Utilizing the authority in paragraph (a) of this section only 
when consistent with the circumstances in that paragraph.
    (d) When in accordance with FAR Subpart 28.3 and FAR 47.102 it is 
determined that a shipment is to be insured or the value declared, the 
vendor will be specifically instructed to do so on the order, when a 
written order is used. If the order is an oral order, all copies of the 
purchase request will be annotated to show that insurance/declared value 
was specifically requested.



847.304  Determination of delivery terms.



847.304-1  General.

    When alternative delivery terms are appropriate but the contracting 
officer elects to use only one in the invitation for bids, or request 
for proposals, he shall document the contract file to show his reasons 
for so doing.



847.305-70  Potential destinations known but quantities unknown.

    When the VA Marketing Center contracts for decentralized procured 
items by all Department of Veterans Affairs installations, the 
evaluation of bids must follow specific procedures. To place each bid on 
an equal basis, even though specific quantities required by each 
hospital cannot be predetermined, an anticipated demand factor will be 
used in proportion to the number of hospital beds or patient workload. 
The clause prescribed in 852.247-70 shall be used in these instances.



PART 849--TERMINATION OF CONTRACTS--Table of Contents




                    Subpart 849.1--General Principles

Sec.
849.106  Fraud or other criminal conduct.
849.107  Audit of prime contract settlement proposals and subcontract 
          settlements.
849.111  Review and approval of proposed settlements.
849.111-70  Settlement review boards.
849.111-71  Required review and approval.
849.111-72  Submission of information.

                 Subpart 849.4--Termination for Default

849.402  Termination of fixed-price contracts for default.
849.402-6  Repurchase against contractor's account.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12628, Mar. 29, 1984, unless otherwise noted.

[[Page 223]]



                    Subpart 849.1--General Principles



849.106  Fraud or other criminal conduct.

    When the circumstances set forth in FAR 49.106 are encountered, the 
contracting officer will immediately discontinue all negotiations. The 
contracting officer will submit all of the pertinent facts necessary to 
support his/her reasoning to the Deputy Assistant Secretary for 
Acquisition and Materiel Management (93), (or the Deputy Assistant 
Secretary for Facilities (08) in the case of contracting officers from 
the Office of Facilities). The Deputy Assistant Secretary for 
Acquisition and Materiel Management (93), or the Office of Facilities 
will review the submission and fully develop the facts. If the evidence 
indicates fraud or other criminal conduct, the Deputy Assistant 
Secretary for Acquisition and Materiel Management will forward the 
submission with his/her recommendations, through channels (to include 
the General Counsel, if appropriate), to the Inspector General (51) for 
referral to the Department of Justice. The contracting officer will be 
advised by the Deputy Assistant Secretary for Acquisition and Materiel 
Management or the Office of Facilities as to any further action to be 
taken. Pending receipt of this advice, the matter will not be discussed 
with the contractor. No collection, recovery or other settlement action 
will be initiated while the matter is in the hands of the Department of 
Justice without first obtaining the concurrence of the U.S. Attorney 
concerned, through the Inspector General. If inquiry is made by the 
contractor, he/she will be advised only that the proposal has been 
forwarded to higher authority.



849.107  Audit of prime contract settlement proposals and subcontract settlements.

    Contracting officers will submit settlement proposals for review and 
audit prior to taking any further action, in accordance with the 
provisions and claim limitations applicable to prime and subcontractors 
as set forth in FAR 49.107. Contracting officers in the Office of 
Acquisition and Materiel Management and Office of Facilities who are 
located in the VA Central Office have the option to request audits 
directly from the cognizant audit agencies or to request audits through 
the Assistant Inspector General for Policy, Planning and Resources 
(53C). All other contracting officers located in the VA Central Office 
and the Office of General Counsel will send requests for audit to the 
Assistant Inspector General for Policy, Planning and Resources (53C), to 
request audits directly from the cognizant agencies. Audit control 
numbers may be obtained verbally from the Deputy Assistant Secretary for 
Acquisition and Materiel Management (93D).
[49 FR 12628, Mar. 29, 1984, as amended at 52 FR 42440, Nov. 5, 1987; 54 
FR 40065, Sept. 29, 1989]



849.111  Review and approval of proposed settlements.



849.111-70  Settlement review boards.

    The Deputy Assistant Secretary for Acquisition and Materiel 
Management and the Deputy Assistant Secretary for Facilities will each 
establish within his/her own organization a settlement review board. The 
board may be established on a permanent or temporary basis. More than 
one such board may be established if settlements are to be made at 
different locations, if personnel with different qualifications are 
needed for different contracts, or if for other reasons, the 
establishment of more than one board is considered desirable. Each 
settlement review board should be composed of at least three qualified 
and disinterested employees. The membership of each board should include 
at least one lawyer and one accountant.



849.111-71  Required review and approval.

    Prior to executing a settlement agreement, or issuing a 
determination of the amount due under the termination clause of a 
contract, or approving or ratifying a subcontract settlement, the 
contracting officer shall submit each such settlement or determination 
for review and approval by a settlement review board if:
    (a) The amount of settlement, by agreement or determination, 
involves $50,000 or more; or

[[Page 224]]

    (b) The settlement or determination is limited to adjustment of the 
fee of a cost-reimbursement contract or subcontract, and:
    (1) In the case of a complete termination, the fee, as adjusted, is 
$50,000 or more; or
    (2) In the case of a partial termination, the fee, as adjusted, with 
respect to the terminated portion of the contract or subcontract is 
$50,000 or more; or
    (c) The head of the contracting activity concerned determines that a 
review of a specific case or class of cases is desirable; or
    (d) The contracting officer, in his/her discretion, desires review 
by the settlement review board.



849.111-72  Submission of information.

    (a) The contracting officer shall submit to the appropriate 
settlement review board a statement of the proposed settlement agreement 
or determination, supported by such detailed information as is required 
for an adequate review. This information should normally include copies 
of:
    (1) The contractor's or subcontractor's settlement proposal,
    (2) The audit report,
    (3) The property disposal report and any required approvals in 
connection therewith,
    (4) The contracting officer's memorandum explaining the settlement, 
and
    (5) Any other relevant material that will assist the board in 
arriving at a decision to approve or disapprove the proposal. The board 
may, in its discretion, require the submission of additional 
information.
    (b) When a review of a proposed settlement is required and the 
contract covers supplies, equipment or services, other than construction 
chargeable to Construction Appropriations, the contracting officer will 
submit the proposed settlement or determination to the settlement review 
board through the Deputy Assistant Secretary for Acquisition and 
Materiel Management.
    (c) When the contract covers construction chargeable to Construction 
Appropriations and review is required, the proposed settlement or 
determination will be submitted by the contracting officer to the 
settlement review board through the Deputy Assistant Secretary for 
Facilities.



                 Subpart 849.4--Termination for Default



849.402  Termination of fixed-price contracts for default.



849.402-6  Repurchase against contractor's account.

    (a) VA Form 90-2237, Request, Turn-in, and Receipt for Property or 
Services, or the file copy of the purchase order covering the purchase 
of supplies, equipment or services against a defaulting contractor shall 
be annotated to show the name of the defaulted contractor, the contract 
number, the contract price, the name of the contractor from whom 
procurement is made, the price paid, the competition secured and the 
difference in cost, if any, to the Department of Veterans Affairs. When 
reprocurement results in the payment of excess costs and the purchase is 
made through the Supply Fund, the excess costs, when collected, shall be 
deposited to the credit of the Supply Fund. In all other instances, the 
excess costs, when collected, shall be deposited to General Fund 
Receipts.
    (b) Contracting officers, when purchasing against a defaulted 
contractor, shall procure the items in a manner that will protect the 
interests of the contractor as well those of the Government.

[[Page 225]]



                     SUBCHAPTER H--CLAUSES AND FORMS





PART 852--SOLICITATION PROVISIONS AND CONTRACT CLAUSES--Table of Contents




      Subpart 852.1--Instructions for Using Provisions and Clauses

Sec.
852.101  Using Part 852.

             Subpart 852.2--Texts of Provisions and Clauses

852.203-70  Ethics in Government Act.
852.203-71  Display of VA hotline poster.
852.207-70  Report of employment under commercial activities.
852.209-70  Organizational conflicts of interest.
852.210-70  Requirements for operating and maintenance manuals.
852.210-71  Guarantee clause.
852.210-72  Inspection.
852.210-73  Frozen processed foods.
852.210-74  Telecommunications equipment.
852.210-75  Technical industry standards.
852.210-76  Noncompliance with packaging, packing and/or marking 
          requirements.
852.210-77  Brand name or equal.
852.212-70  Liquidated damages.
852.214-70  Caution to bidders--bid envelopes.
852.214-71  Alternate items.
852.214-73  Bid samples.
852.216-70  Estimated quantities for requirements contracts.
852.219-70  Veteran-owned small business.
852.222-70  Contract Work Hours and Safety Standards Act--nursing home 
          care contract supplement.
852.228-70  Bond premium adjustment.
852.229-70  Purchases from patient's funds.
852.229-71  Purchases for patients using Government funds and/or 
          personal funds of patients.
852.233-70  Protest content.
852.236-70  Clauses and provisions for fixed-price construction 
          contracts.
852.236-71  Specifications and drawings for construction.
852.236-72  Performance of work by the contractor.
852.236-73  Bonds.
852.236-74  Inspection of construction.
852.236-75  Guaranty.
852.236-76  Correspondence.
852.236-77  Reference to ``standards''.
852.236-78  Government supervision.
852.236-79  Daily report of workers and materials.
852.236-80  Subcontracts and work coordination.
852.236-81  Work coordination (alternate provision).
852.236-82  Payments under fixed-price construction contracts (without 
          NAS).
852.236-83  Payments under fixed-price construction contracts (including 
          NAS).
852.236-84  Schedule of work progress.
852.236-85  Supplementary labor standards provisions.
852.236-86  Workman's compensation.
852.236-87  Accident prevention.
852.236-88  Contract changes.
852.236-89  Buy American Act.
852.236-90  Restriction on submission and use of equal products.
852.236-91  Special notes.
852.237-7  Indemnification and Medical Liability Insurance.
852.237-70  Contractor responsibilities.
852.237-71  Indemnification and insurance (vehicle and aircraft service 
          contracts).
852.247-70  Transportation provision for bid evaluation.
852.270-1  Representatives of contracting officers.
852.270-2  Bread and bakery products.
852.270-3  Purchase of shell fish.
852.270-4  Commercial advertising.
852.271-70  Services provided eligible beneficiaries.
852.271-71  Visits to Department of Veterans Affairs guidance centers.
852.271-72  Time spent by counselee in counseling process.
852.271-73  Use and publication of counseling results.
852.271-74  Inspection.
852.271-75  Extension of contract period.

    Authority:  38 U.S.C. 501; 40 U.S.C. 486(c)



      Subpart 852.1--Instructions for Using Provisions and Clauses



852.101  Using Part 852.

    Part 852 prescribes supplemental provisions and clauses to the FAR. 
Provision and clause numbering are as prescribed in FAR 52.101 (e.g, 
supplementary Architect-Engineer and Construction clauses are numbered 
852.236-70, 852.236-71, etc.).
[50 FR 794, Jan. 7, 1985]



             Subpart 852.2--Texts of Provisions and Clauses



852.203-70  Ethics in Government Act.

    As prescribed by 803.101-3 the following provision will be made a 
part of all solicitations and requests for proposals

[[Page 226]]

anticipated to result in contracts exceeding the small purchase 
limitation:

        Certification for the Ethics in Government Act (Apr 1984)

    The offeror certifies that in developing a proposal in response to 
the solicitation of this contract, he/she did not utilize the services 
of any former Department of Veterans Affairs employee acting in 
violation of Title V of the Ethics in Government Act, 18 U.S.C. 207. 
That law provides that:
    (a) A former Department of Veterans Affairs employee who, as such an 
employee, personally and substantially participated in a particular 
procurement process, is prohibited from appearing before the Department 
on behalf of an offeror responding to a solicitation resulting from that 
process and from making any contact with the Department on behalf of the 
offeror with intent of influencing action related to the solicitation;
    (b) A former Department of Veterans Affairs employee who, during the 
last year as such an employee, was officially responsible for a 
particular procurement process, is prohibited, for two years after 
leaving the Department of Veterans Affairs, from appearing before the 
Department on behalf of an offeror responding to a solicitation 
resulting from that process and from making any contact with the 
Department on behalf of the offeror with the intent of influencing 
action related to the solicitation;
    (c) Any former top-level Department of Veterans Affairs employee 
(i.e., executive-level employee; employee paid at the rate of GS-17 or 
above if designated pursuant to 5 CFR 737.25(b); and Senior Executive 
Service employee if designated pursuant to 5 CFR 737.25(b)) who, as such 
an employee, personally and substantially participated in a particular 
procurement process, is prohibited, for a period of two years, from 
representing, aiding, consulting, or assisting an offeror by presence 
before the Government at any formal or informal appearance related to 
that procurement process;
    (d) For a period of one year, any former top-level employee of the 
Department of Veterans Affairs (as described in the preceding paragraph) 
is prohibited from appearing before the Department of Veterans Affairs 
on behalf of any offeror responding to a contract solicitation and is 
prohibited from making any oral or written communications with the 
Department of Veterans Affairs on behalf of such an offeror, with the 
intent of influencing action related to a contract.

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 54 
FR 40065, Sept. 29, 1989]



852.203-71  Display of VA hotline poster.

    As prescribed in 803.7002, insert the following clause:

                      Display of VA Hotline Poster

    (a) Except as provided in paragraph (c) below, the Contractor shall 
display prominently in common work areas within business segments 
performing work under VA contracts, VA Hotline posters prepared by the 
VA Office of the Inspector General.
    (b) VA Hotline posters may be obtained from the VA Office of 
Inspector General (53E), P.O. Box 34647, Washington, DC 20043-4647.
    (c) The Contractor need not comply with paragraph (a) above, if the 
Contractor has established a mechanism, such as a hotline, by which 
employees may report suspected instances of improper conduct, and 
instructions that encourage employees to make such reports.

                             (End of clause)

[57 FR 58718, Dec. 11, 1992]



852.207-70  Report of employment under commercial activities.

    As prescribed in 807.304-75, the following clause will be included 
in A-76 cost comparison solicitations:

     Report of Employment Under Commercial Activities (October 1988)

    (a) Consistent with the Government post-employment conflict of 
interest regulations, the contractor shall give adversely affected 
Federal employees the right of first refusal for all employment openings 
under this contract for which they are qualified.
    (b) Definitions. (1) An ``adversely affected Federal employee'' is:
    (i) Any permanent Federal employee who is assigned to the government 
commercial activity, or
    (ii) Any employee identified for release from his or her competitive 
level or separated as a result of the contract.
    (2) ``Employment openings'' are position vacancies created by this 
contract which the contractor is unable to fill with personnel in the 
contractor's employee at the time of the contract award, including 
positions within a 50 mile radius of the commercial activity which 
indirectly arise in the contractor's organization as a result of the 
contractor's reassignment of employees due to the award of this 
contract.
    (3) The ``contract start date'' is the first day of contractor 
performance.
    (c) Filling employment openings. (1) For a period beginning with 
contract award and ending 90 days after the contract start date, no

[[Page 227]]

person other than an adversely affected Federal employee on the current 
listing provided by the contracting officer shall be offered an 
employment opening until all adversely affected and qualified Federal 
employees identified by the contracting officer have been offered the 
job and refused it.
    (2) The contractor may select any person for an employment opening 
when there are no qualified adversely affected Federal employees on the 
latest current listing provided by the contracting officer.
    (d) Contracting reporting requirements. (1) No later than five 
working days after contract award the contractor shall furnish the 
contracting officer with the following:
    (i) A list of employment openings including salaries and benefits,
    (ii) Sufficient job application forms for adversely affected Federal 
employees.
    (2) By contract start date, the contractor shall provide the 
contracting officer with the following:
    (i) The names of adversely affected Federal employees offered an 
employment opening,
    (ii) The date the offer was made,
    (iii) A brief description of the position,
    (iv) The date of acceptance of the offer and the effective date of 
employment,
    (v) The date of rejection of the offer, if applicable for salary and 
benefits contained in the rejected offer, and
    (vi) The names of any adversely affected Federal employees who 
applied but were not offered employment and the reason(s) for 
withholding an offer.
    (3) For the first 90 days after the contract start date, the 
contractor shall provide the contracting officer with the names of all 
persons hired or terminated under the contract within five working days 
of such hiring or termination.
    (e) Information provided to the contractor. (1) No later than 10 
working days after the contract award, the contracting officer shall 
furnish the contractor a current list of adversely affected Federal 
employees exercising the right of first refusal, along with their 
completed job application forms.
    (2) Between the contract award and start dates, the contracting 
officer shall inform the contractor of any reassignment or transfer of 
adversely affected employees to other Federal positions.
    (3) For a period up to 90 days after contract start date, the 
contracting officer will periodically provide the contractor with an 
updated listing of adversely affected Federal employees reflecting 
employees recently released from their competitive levels or separated 
as a result of the contract award.
    (f) Qualification determination. The contractor has a right under 
this clause to determine adequacy of the qualifications of adversely 
affected Federal employees for any employment openings. However, an 
adversely affected Federal employee who held a job in the Government 
commercial activity which directly corresponds to an employment opening 
shall be considered qualified for the job. Questions concerning the 
qualifications of adversely affected Federal employees for specific 
employment openings shall be referred to the contracting officer for 
determination. The contracting officer's determination shall be final 
and binding on all parties.
    (g) Relation to other statutes, regulations and employment policies. 
The requirements of this clause shall not modify or alter the 
contractor's responsibilities under statutes, regulations or other 
contract clauses pertaining to the hiring of veterans, minorities or 
handicapped persons.
    (h) Penalty for Noncompliance. Failure of the contractor to comply 
with any provision of this clause may be grounds for termination for 
default.

                             (End of clause)

[53 FR 43211, Oct. 26, 1988; 53 FR 46872, Nov. 21, 1988]



852.209-70  Organizational conflicts of interest.

    The following provision will be used as prescribed in 809.508-2:

             Organizational Conflicts of Interest (Apr 1984)

    (a) The offeror represents to the best of his/her knowledge and 
belief that the award of the contract would not involve organizational 
conflicts of interest as defined in this representation. The term 
organizational conflicts of interests shall mean that a relationship 
exists whereby an offeror or a contractor (including his/her chief 
executive, directors, proposed consultants and subcontractors) has 
interests which may: (1) Diminish his/her capacity to give impartial, 
technically sound, objective assistance and advice or may otherwise 
result in a biased work product; or (2) result in an unfair competitive 
advantage. It does not include the ``normal flow of benefits'' from the 
performance of a contract.
    (b) Based on this representation and any other information solicited 
by the contracting officer, it may be determined organizational 
conflicts of interest exist which would warrant disqualifying the 
contractor for award of the contract unless the organizational conflicts 
of interest can be mitigated to the contracting officer's satisfaction 
by negotiating terms and conditions of the contract to that effect. In 
the case of a formally advertised solicitation, the apparent successful 
offeror may enter into a supplemental agreement which mitigates the 
organizational conflicts of interest.

[[Page 228]]

    (c) Nondisclosure or misrepresentations of organizational conflicts 
of interest at the time of the offer, or arising as a result of a 
modification to the contract, may result in the termination of the 
contract at no expense to the Government.

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.210-70  Requirements for operating and maintenance manuals.

    (a) Solicitations and requests for proposals for technical medical 
and other technical equipment and devices issued by a field facility 
will normally require the contractor to provide operating and 
maintenance manuals.
    (b) The purpose of the requirement is for the manufacturer to 
provide the Department of Veterans Affairs a manual or groups of manuals 
that will allow the in-house repair of the equipment purchased. Unless 
the facility Chief, Engineering Service, indicates that such service 
manuals are not needed, each invitation for bid or request for proposal 
for technical medical or other technical equipment and devices will 
include the following clauses for operating and maintenance manuals:

                     Service Data Manual (Nov 1984)

    (a) The successful bidder will supply operation/service 
(maintenance) manuals with each piece of equipment in the quantity 
specified in the solicitation and resulting purchase order. As a 
minimum, the manual(s) shall be bound and equivalent to the manual(s) 
provided the manufacturer's designated field service representative as 
well as comply with all the requirements in paragraphs (b) through (i) 
of this clause. Sections, headings and section sequence identified in 
(b) through (i) of this clause are typical and may vary between 
manufacturers. Variances in the sections, headings and section sequence, 
however, do not relieve the manufacturer of his responsibility in 
supplying the technical data called for therein.
    (b) Title Page and Front Matter--The title page shall include the 
equipment nomenclature, model number, effective date of the manual and 
the manufacturer's name and address. If the manual applies to a 
particular version of the equipment only, the title page shall also list 
that equipment's serial number. Front matter shall consist of the Table 
of Contents, List of Tables, List of Illustrations and a frontispiece 
(photograph or line drawing) depicting the equipment.
    (c) Section I, General Description--This section shall provide a 
generalized description of the equipment or devices and shall describe 
its purpose or intended use. Included in this section will be a table 
listing all pertinent equipment specifications, power requirements, 
environmental limitations and physical dimensions.
    (d) Section II, Installation--Section II shall provide pertinent 
installation information. It shall list all input and output connectors 
using applicable reference designators and functional names as they 
appear on the equipment. Included in this listing will be a brief 
description of the function of each connector along with the connector 
type. Instructions shall be provided as to the recommended method of 
repacking the equipment for shipment (packing material, labeling, etc.).
    (e) Section III, Operation--Section III will fully describe the 
operation of the equipment and shall include a listing of each control 
with a brief description of its function and step-by-step procedures for 
each operating mode. Procedures will use the control(s) nomenclature as 
it appears on the equipment and will be keyed to one or more 
illustrations of the equipment. Operating procedures will include any 
preoperational checks, calibration adjustments and operation tests. 
Notes, cautions and warnings shall be set off from the text body so they 
may easily be recognizable and will draw the attention of the reader. 
Illustrations should be used wherever possible depicting equipment 
connections for test, calibration, patient monitoring and measurements. 
For large, complex and/or highly versatile equipment capable of many 
operating modes and in other instances where the Operation Section is 
quite large, operational information may be bound separately in the form 
of an Operators Manual. The providing of a separate Operators Manual 
does not relieve the supplier of his responsibility for providing the 
minimum acceptable maintenance data specified herein.
    Where applicable, flow charts and narrative descriptions of software 
shall be provided. If programming is either built-in and/or user 
modifiable, a complete software listing shall be supplied. Equipment 
items with software packages shall also include diagnostic routines and 
sample outputs. Submission information shall be given in the Maintenance 
Section to identify equipment malfunctions which are software related.
    (f) Section IV, Principles of Operation-- This section shall 
describe in narrative form the principles of operation of the equipment. 
Circuitry shall be discussed in sufficient detail to be understood by 
technicians and engineers who possess a working knowledge of electronics 
and a general familiarity with the overall application of the devices. 
The

[[Page 229]]

circuit descriptions should start at the overall equipment level and 
proceed to more detailed circuit descriptions. The overall description 
shall be keyed to a functional block diagram of the equipment. Circuit 
descriptions shall be keyed to schematic diagrams discussed in paragraph 
(i) below. It is recommended that for complex or special circuits, 
simplified schematics should be included in this section.
    (g) Section V, Maintenance-- The maintenance section shall contain a 
list of recommended test equipment, special tools, preventive 
maintenance instructions and corrective information. The list of test 
equipment shall be that recommended by the manufacturer and shall be 
designated by manufacturer and model number. Special tools are those 
items not commercially available or those that are designed specifically 
for the equipment being supplied. Sufficent data will be provided to 
enable their purchase by the Department of Veterans Affairs. Preventive 
maintenance instructions shall consist of those recommended by the 
manufacturer to preclude unnecessary failures. Procedures and the 
recommended frequency of performance shall be included for visual 
inspection, cleaning, lubricating, mechanical adjustments and circuit 
calibration. Corrective maintenance shall consist of the data necessary 
to troubleshoot and rectify a problem and shall include procedures for 
realigning and testing the equipment. Troubleshooting shall include 
either a list of test points with the applicable voltage levels or 
waveforms that would be present under a certain prescribed set of 
conditions, a troubleshooting chart listing the symptom, probable cause 
and remedy, or a narrative containing sufficient data to enable a test 
technician or electronics engineer to determine and locate the probable 
cause of malfunction. Data shall also be provided describing the 
preferred method of repairing or replacing discrete components mounted 
on printed circuit boards or located in areas where special steps must 
be followed to disassemble the equipment. Procedures shall be included 
to realign and test the equipment at the completion of repairs and to 
restore it to its original operating condition. These procedures shall 
be supported by the necessary waveforms and voltage levels, and data for 
selecting matched components. Diagrams, either photographic or line, 
shall show the location of printed circuit board mounted components.
    (h) Section VI, Replacement Parts List--The replacement parts list 
shall list, in alphanumeric order, all electrical/electronic, mechanical 
and pneumatic components, their description, value and tolerance, true 
manufacturer and manufacturers' part number.
    (i) Section VII, Drawings--Wiring and schematic diagrams shall be 
included. The drawings will depict the circuitry using standard symbols 
and shall include the reference designations and component values or 
type designators. Drawings shall be clear and legible and shall not be 
engineering or productions sketches.

                             (End of clause)

    (c) Solicitations and requests for proposals for mechanical 
equipment (other than technical medical equipment and devices) issued by 
a field facility will include the following clause:

                     Service Data Manual (Nov 1984)

    The contractor agrees to furnish two copies of a manual, handbook or 
brochure containing operating, installation, and maintenance 
instructions (including pictures or illustrations, schematics, and 
complete repair/test guides as necessary). Where applicable, it will 
include electrical data and connection diagrams for all utilities. The 
instructions shall also contain a complete list of all replaceable parts 
showing part number, name, and quantity required.

                             (End of clause)

    (d) When the bid or proposal will result in the initial purchase 
(including each make and model) of a centrally procured item, the 
following clause will be used:

                     Service Data Manual (Nov 1984)

    The contractor agrees, when requested by the contracting officer, to 
furnish not more than three copies of the technical documentation 
required by paragraph 852.210-70(a) to the Service and Reclamation 
Division, VA Supply Depot, Hines, Ill. In addition, the contractor 
agrees to furnish two additional copies of the technical documentation 
required by 852.210-70(a) above with each piece of equipment sold as a 
result of the invitation for bid or request for proposal.

                             (End of clause)

[50 FR 795, Jan. 7, 1985; 54 FR 40065, Sept. 29, 1989; 61 FR 11587, Mar. 
21, 1996]



852.210-71  Guarantee clause.

    (a) When the bid or proposal will result in any purchase of 
equipment, the following clause will be used:

                          Guarantee (Nov 1984)

    The contractor guarantees the equipment against defective material, 
workmanship and

[[Page 230]]

performance for a period of ______,\1\ said guarantee to run from date 
of acceptance of the equipment by the Government. The contractor agrees 
to furnish, without cost to the Government, replacement of all parts and 
material which are found to be defective during the guarantee period. 
Replacement of material and parts will be furnished to the Government at 
the point of installation, if installation is within the continental 
United States, or f.o.b. the continental U.S. port to be designated by 
the contracting officer if installation is outside of the continental 
United States. Cost of installation of replacement material and parts 
shall be borne by the contractor. \2\
---------------------------------------------------------------------------

    \1\ Normally, insert one year. If industry policy covers a shorter 
or longer period, i.e., 90 days or for the life of the equipment, insert 
such period.
    \2\ The above clause will be modified to conform to standards of the 
industry involved.
---------------------------------------------------------------------------

                             (End of clause)

    (b) Where it is industry policy to furnish, but not install, 
replacement material and parts at the contractor's expense, the last 
sentence will be changed to indicate that cost of installation shall be 
borne by the Government. Where it is industry policy to: (1) Guarantee 
components for the life of the equipment (i.e., crystals in transmitters 
and receivers in radio communications systems); or (2) require that 
highly technical equipment be returned to the factory (at contractor's 
or Government's expense) for replacement of defective materials or 
parts, the clause used will be compatible with such policy.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan. 7, 1985]



852.210-72  Inspection.

    (a) Contracts for property, other than packing house and dairy 
products and fresh and frozen fruits and vegetables will contain the 
following clause:

                        Rejected Goods (Nov 1984)

    Rejected goods will be held subject to contractor's order for not 
more than 15 days, after which the rejected merchandise will be returned 
to the contractor's address at his/her risk and expense. Expenses 
incident to the examination and testing of materials or supplies which 
have been rejected will be charged to the contractor's account.

                             (End of clause)

    (b) Contracts for packinghouse and dairy products, bread and bakery 
products and for fresh and frozen fruits and vegetables will contain the 
following clause:

                             Rejected Goods

    The contractor shall remove rejected supplies within 48 hours after 
notice of rejection. Supplies determined to be unfit for human 
consumption will not be removed without permission of the local health 
authorities. Supplies not removed within the allowed time may be 
destroyed. The Department of Veterans Affairs will not be responsible 
for nor pay for products rejected. The contractor will be liable for 
costs incident to examination of rejected products.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.210-73  Frozen processed foods.

    The following clause will be included in all solicitations for the 
purchase of frozen processed foods, issued by a field facility:

                    Frozen Processed Foods (Nov 1984)

    The products delivered under this contract shall be in excellent 
condition, shall not show evidence of defrosting, refreezing, or freezer 
burn and shall be transported and delivered to the consignee at a 
temperature of 0 degrees Fahrenheit or lower.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan. 7, 1985; 
54 FR 40065, Sept. 29, 1989]



852.210-74  Telecommunications equipment.

    (a) When a detailed purchase description of formal specification is 
the basis for solicitations for telecommunications equipment as defined 
in VA Manual MP-6, Part VIII, (available at any Department of Veterans 
Affairs facility), solicitations, including those for construction, will 
include the following provision:

                        Special Notice (Apr 1984)

    Descriptive literature. The submission of descriptive literature 
with offers is not required and voluntarily submitted descriptive 
literature which qualifies the offer will require rejection of the 
offer.

[[Page 231]]

    However, within 5 days after award of contract, the contractor will 
submit to the contracting officer literature describing the equipment 
he/she intends to furnish and indicating strict compliance with the 
specification requirements.
    The contracting officer will, by written notice to the contractor 
within 20 calendar days after receipt of the literature, approve, 
conditionally approve, or disapprove the equipment proposed to be 
furnished. The notice of approval or conditional approval will not 
relieve the contractor from complying with all requirements of the 
specifications and all other terms and conditions of this contract. A 
notice of conditional approval will state any further action required of 
the contractor. A notice of disapproval will cite reasons therefor.
    If the equipment is disapproved by the Government, the contractor 
will be subject to action under the Default provision of this contract. 
However, prior to default action the contractor will be permitted a 
period (at least 10 days) under that clause to submit additional 
descriptive literature on equipment originally offered or descriptive 
literature on other equipment.
    The Government reserves the right to require an equitable adjustment 
of the contract price for any extension of the delivery schedule 
necessitated by additional descriptive literature evaluations.

                           (End of Provision)

    (b) The descriptive literature to be furnished by the contractor 
after award in accordance with paragraph (a) of this section is subject 
to the controls established in 870.112(b).
    (c) The time of delivery or performance to be specified in the 
solicitation will include the time required for submission, receipt, the 
evaluation and approval required by 870.112(b) of this chapter, and 
return to the contractor of the descriptive literature.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan. 7, 1985]



852.210-75  Technical industry standards.

    When items are required to conform to technical industry standards, 
such as those adopted by Underwriter's Laboratories, Incorporated; 
Factory Mutual Laboratories; American Gas Association; American Society 
Mechanical Engineers; National Electrical Manufacturers' Association; 
American Society Heating, Refrigeration and Air Conditioning Engineers; 
or similar organizations where such standards are generally recognized 
and accepted in the industry involved, the invitation for bids, request 
for proposals or request for quotations will so state. In no instance, 
where there is a multiple choice of laboratories, shall the invitation 
for bid, request for proposal or request for quotation indicate that the 
label or certificate of only one such laboratory is acceptable. The 
following provision will be used unless comparable provisions are 
contained in the item specification:

                 Technical Industry Standards (Apr 1984)

    The supplies or equipment required by this invitation for bid or 
request for proposal must conform to the standards of the ______\3\ and 
______\3\ as to ______.\4\ The successful bidder or offeror will be 
required to submit proof that the item(s) he furnishes conforms to this 
requirement. This proof may be in the form of a label or seal affixed to 
the equipment or supplies, warranting that they have been tested in 
accordance with and conform to the specified standards. The seal or 
label of any nationally recognized laboratory such as those listed by 
the National Fire Protection Association, Boston, Massachusetts, in the 
current edition of their publication ``Research on Fire,'' is 
acceptable. Proof may also be furnished in the form of a certificate 
from one of these laboratories certifying that the item(s) furnished 
have been tested in accordance with and conform to the specified 
standards.
---------------------------------------------------------------------------

    \3\ Insert name(s) of organization(s), the standards of which are 
pertinent to the Government's needs.
    \4\ Insert pertinent standards, i.e. fire and casualty, safety and 
fire protection, etc.
---------------------------------------------------------------------------

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan. 7, 1985]



852.210-76  Noncompliance with packaging, packing, and/or marking requirements.

    The following clause will be included in contracts for supplies for 
delivery to supply distribution warehouses or depots for storage and 
subsequent issue to a using activity. It may also be included when 
appropriate when delivery is direct to a using activity.

[[Page 232]]

 Noncompliance with Packaging, Packing and/or Marking Requirements (JUL 
                                  1989)

    Failure to comply with the packaging, packing, and/or marking 
requirements indicated herein, or incorporated herein by reference, may 
result in rejection of the merchandise and request for replacement or 
repackaging, repacking, and/or marking. The Government reserves the 
right, without obtaining authority from the contractor, to perform the 
required repackaging, repacking, and/or marking services and charge the 
contractor at the actual cost to the Government for the same or have the 
required repackaging, repacking, and/or marking services performed 
commercially under Government order and charge the contractor at the 
invoice rate. In connection with any discount offered, time will be 
computed from the date of completion of such repackaging, repacking, 
and/or marking services.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 54 
FR 30045, July 18, 1989; 61 FR 11587, Mar. 21, 1996]



852.210-77  Brand name or equal.

    The brand name or equal clause when used as prescribed by 810.004 
will be as follows:

                     Brand Name or Equal (Nov 1984)

    (Note: As used in this clause, the term ``brand name'' includes 
identification of products by make and model.)
    (a) If items called for by this invitation for bids have been 
identified in the schedule by a ``brand name or equal'' description, 
such identification is intended to be descriptive, but not restrictive, 
and is to indicate the quality and characteristics of products that will 
be satisfactory. Bids offering ``equal'' products (including products of 
the brand name manufacturer other than the one described by brand name) 
will be considered for award if such products are clearly identified in 
the bids and are determined by the Government to meet fully the salient 
characteristics requirements listed in the invitation.
    (b) Unless the bidder clearly indicates in his bid that he is 
offering an ``equal'' product, his bid shall be considered as offering a 
brand name product referenced in the invitation for bids.
    (c)(1) If the bidder proposes to furnish an ``equal'' product, the 
brand name, if any, of the product to be furnished shall be inserted in 
the space provided in the Invitation for Bids, or such product shall be 
otherwise clearly identified in the bid. The evaluation of bids and the 
determination as to equality of the product offered shall be the 
responsibility of the Government and will be based on information 
furnished by the bidder or identified in his/her bid as well as other 
information reasonably available to the purchasing activity. CAUTION TO 
BIDDERS. The purchasing activity is not responsible for locating or 
securing any information which is not identified in the bid and 
reasonably available to the purchasing activity. Accordingly, to insure 
that sufficient information is available, the bidder must furnish as a 
part of his/her bid all descriptive material (such as cuts, 
illustration, drawings or other information) necessary for the 
purchasing activity to: (i) Determine whether the product offered meets 
the salient characteristics requirement of the Invitation for Bids, and 
(ii) establish exactly what the bidder proposes to furnish and what the 
Government would be binding itself to purchase by making an award. The 
information furnished may include specific references to information 
previously furnished or to information otherwise available to the 
purchasing activity.
    (2) If the bidder proposes to modify a product so as to make it 
conform to the requirements of the Invitation for Bids, he/she shall: 
(i) Include in his/her bid a clear description of such proposed 
modifications, and (ii) clearly mark any descriptive material to show 
the proposed modifications.
    (3) Modifications proposed after bid opening to make a product 
conform to a brand name product referenced in the Invitation for Bids 
will not be considered.

                             (End of clause)

[50 FR 796, Jan. 7, 1985, as amended at 53 FR 7756, Mar. 10, 1988]



852.212-70  Liquidated damages.

    As prescribed in 812.204 and 836.206, the contracting officer may 
insert the following clause when appropriate:

              Partial Performance and Acceptance (Apr 1984)

    If any unit of the work contracted for is accepted in advance of the 
whole, the rate of liquidated damages assessed will be in the ratio that 
the value of the unaccepted work bears to the total amount of the 
contract. If a separate price for unaccepted work has not been stated in 
the contractor's bid, determination of the value thereof will be made 
from schedules of costs furnished by the contractor and approved by the 
contracting officer, as specified elsewhere in the contract.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]

[[Page 233]]



852.214-70  Caution to bidders--bid envelopes.

    As provided in 814.201, the following provision will be prominently 
placed on all IFB's:

              Caution to Bidders--Bid Envelopes (Apr 1984)

    It is the responsibility of each bidder to take all necessary 
precautions, including the use of a proper mailing cover, to insure that 
the bid price cannot be ascertained by anyone prior to bid opening. If a 
bid envelope is furnished with this invitation, the bidder is requested 
to use this envelope in submitting the bid. The bidder may, however, 
when it suits a purpose, use any suitable envelope, identified by the 
invitation number and bid opening time and date. If a bid envelope is 
not furnished, the bidder will complete and affix the enclosed Optional 
Form 17, Sealed Bid Label, to the lower left-hand corner of the envelope 
used in submitting the bid.

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.214-71  Alternate items.

    As prescribed in 814.201, consideration of alternate items may be 
appropriate. The following provisions may be used under the specified 
conditions:
    (a) When an alternate item is to be considered only if no bids or 
insufficient bids are received on the item desired, the following will 
be included in the invitation:

                      Alternate Item(s) (Apr 1984)

    Bids on ______ 5 will be considered only if acceptable 
bids on ______ 6 are not received or do not satisfy the total 
requirement.
---------------------------------------------------------------------------

    5 Contracting officer will insert an alternate item that 
is considered acceptable.
    6 Contracting officer will insert the required item and 
item number.
---------------------------------------------------------------------------

                           (End of Provision)

    (b) When an alternate item will be considered on an equal basis with 
the item specified, the following will be included in the invitation:

                      Alternate Item(s) (Apr 1984)

    Bids ______ 5 will be given equal consideration along 
with the ______ 6 and any such bids received may be accepted 
if to the advantage of the Government. Tie bids will be decided in favor 
of.6

                        (End of Provision)

    (c) In addition to the clause in paragraph (a) or (b) of this 
section, the following provision will be included in the invitation when 
bids will be allowed on different packaging, unit designation, etc.

               Alternate Packaging and Packing (Apr 1984)

    The bidder's offer must clearly indicate the quantity, package size, 
unit, or other different feature upon which the quote is made. 
Evaluation of the alternate or multiple alternates will be made on a 
common denominator such as per ounce, per pound, etc., basis.

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan. 7, 1985]



852.214-73  Bid samples.

    As prescribed in 814.202-4, insert the following provision:

                      Bid Samples (September 1993)

    Any bid sample(s) furnished must be in the quantities specified in 
the solicitation and plainly marked with the complete lettering/
numbering and description of the related bid item(s); the number of the 
Invitation for Bids; and the name of the bidder submitting the bid 
sample(s). Cases or packages containing any bid sample(s) must be 
plainly marked ``Bid Sample(s)'' and all charges pertaining to the 
preparation and transportation of bid sample(s) must be prepaid by the 
bidder. Bid sample(s) must be received at the location specified in the 
solicitation by the time and date for receipt of bids.

                           (End of Provision)

[58 FR 48974, Sept. 21, 1993]



852.216-70  Estimated quantities for requirements contracts.

    (a) When definite quantities cannot be determined, solicitations for 
facility-level requirements contracts will contain the applicable clause 
as set forth below. Solicitations issued by the Marketing Center will 
contain provisions developed by that Center for particular application 
to its operations, subject to legal review as prescribed in 801.602-
70(c)(1).
    (b) The following clause will be used for general equipment, 
supplies and services:

[[Page 234]]

                     Estimated Quantities (Apr 1984)

    As it is impossible to determine the exact quantities that will be 
required during the contract term, each bidder whose bid is accepted 
wholly or in part will be required to deliver all articles or services 
that may be ordered during the contract term, except as he/she otherwise 
indicates in his/her bid and except as otherwise provided herein. Bids 
will be considered if made with the proviso that the total quantities 
delivered shall not exceed a certain specified quantity. Bids offering 
less than 75 percent of the estimated requirement or which provide that 
the Government shall guarantee any definite quantity, will not be 
considered. The fact that quantities are estimated shall not relieve the 
contractor from filling all orders placed under this contract to the 
extent of his/her obligation. Also, the Department of Veterans Affairs 
shall not be relieved of its obligation to order from the contractor all 
articles or services that may, in the judgment of the ordering officer, 
be needed except that in the public exigency procurement may be made 
without regard to this contract.

                             (End of clause)

    (c) The following clause will be used in local coal-hauling 
contracts.

                           Estimated Quantity

    The estimated requirements shown in this invitation for bids cover 
the requirements for the entire contract period. It is understood and 
agreed that during the period of this contract the Government may order 
and the contractor will haul such coal as may, in the opinion of the 
Government, be required, except that in the public exigency procurement 
may be made without regard to this contract.

                             (End of clause)

    (d) The following clause will be used for orthopedic, prosthetic, 
and optical supplies.

                               Quantities

    The supplies and/or services listed in the attached schedule will be 
furnished at such time and in such quantities as they are required.

                             (End of clause)

    (e) The following clause will be used for National Cemetery System 
contracts for monuments:

                    Estimated Quantities (July 1989)

    As it is impossible to determine the exact quantities that will be 
required during the contract term, each bidder whose bid is accepted 
wholly or in part will be required to deliver all articles that may be 
ordered during the contract term, except as he or she otherwise 
indicates in his or her bid and except as otherwise provided herein. 
Bids will be considered if made with the proviso that the total 
quantities delivered shall not exceed a certain specified quantity. The 
fact that quantities are estimated shall not relieve the contractor from 
filling all orders placed under this contract to the extent of his or 
her obligation. Also, the Department of Veterans Affairs shall not be 
relieved of its obligation to order from the contractor all articles 
that may, in the judgment of the ordering officer, be needed except that 
in the public exigency procurement may be made without regard to this 
contract.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan. 7, 1985; 
54 FR 30045, July 18, 1989]



852.219-70  Veteran-owned small business.

    As prescribed in 819.7003(a), the following certification will be 
made a part of all solicitations and all requests for quotations:

                 Veteran-Owned Small Business (DEC 1990)

    The offeror represents that the firm submitting this offer ( ) is ( 
) is not, a veteran-owned small business, ( ) is ( ) is not, a Vietnam 
era veteran-owned small business, and ( ) is ( ) is not, a disabled 
veteran-owned small business. A veteran-owned small business is defined 
as a small business, at least 51 percent of which is owned by a veteran 
who also controls and operates the business. Control in this context 
means exercising the power to make policy decisions. Operate in this 
context means actively involved in day-to-day management. For the 
purpose of this definition, eligible veterans include:
    (a) A person who served in the U.S. Armed Forces and who was 
discharged or released under conditions other than dishonorable.
    (b) Vietnam era veterans who served for a period of more than 180 
days, any part of which was between August 5, 1964, and May 7, 1975, and 
were discharged under conditions other than dishonorable.
    (c) Disabled veterans with a minimum compensable disability of 30 
percent, or a veteran who was discharged for disability.

Failure to execute this representation will be deemed a minor 
informality and the bidder or offeror shall be permitted to satisfy the 
requirement prior to award (see FAR 14.405).


[[Page 235]]


(End of Provision)
[50 FR 796, Jan. 7, 1985; 54 FR 40065, Sept. 29, 1989, as amended at 55 
FR 49901, Dec. 3, 1990; 61 FR 11587, Mar. 21, 1996]



852.222-70  Contract Work Hours and Safety Standards Act--nursing home care contract supplement.

    As prescribed in 822.304, nursing home care contracts will include 
the following clause.

 Contract Workhours and Safety Standard Act--Nursing Home Care Contract 
                          Supplement (Apr 1984)

    In the performance of any contract entered into pursuant to the 
provisions of 38 U.S.C. 620 to provide nursing home care of veterans, no 
contractor or subcontractor under such contract shall be deemed in 
violation of Section 102 of the Contract Work Hours and Safety Standards 
Act by virtue of failure to pay the overtime wages required by such 
section for work in excess of 8 hours in any calendar day or 40 hours in 
the workweek to any individual employed by establishment which is an 
institution primarily engaged in the care of the sick, the aged, or the 
mentally ill or defective who reside on the premises if, pursuant to an 
agreement or understanding arrived at between the employer and the 
employee before performance of the work, a work period of 14 consecutive 
days is accepted in lieu of the workweek of 7 consecutive days for the 
purpose of overtime compensation and if such individual receives 
compensation for employment in excess of 8 hours in any workday and in 
excess of 80 hours in such 14-day period at a rate not less than 1\1/2\ 
times the regular rate at which the individual is employed, computed in 
accordance with the requirements of the Fair Labor Standards Act of 
1938, as amended.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.228-70  Bond premium adjustment.

    The following clause will be utilized as prescribed by 828.7000.

                   Bond Premium Adjustment (Apr 1984)

    When net changes in original contract price affect the premium of a 
Corporate Surety Bond by $5 or more, the Government in determining basis 
for final settlement, will provide for bond premium adjustment computed 
at the rate shown in the bond.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.229-70  Purchases from patient's funds.

    When contracts are for items to be purchased solely from personal 
funds of patients, the following tax provision will be used in lieu of 
the Federal, State and local tax clause in FAR 52.229-1.

                      Sales or Use Taxes (Apr 1984)

    The articles listed in this bid invitation will be purchased from 
personal funds of patients and prices bid herein include any sales or 
use tax heretofore imposed by any State, or by any duly constituted 
taxing authority therein, having jurisdiction to levy such a tax, 
applicable to the material in this bid.

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan.7, 1985



852.229-71  Purchases for patients using Government funds and/or personal funds of patients.

    When contracts are for items to be purchased from both Government 
funds and personal funds of patients, the following provision will be 
included as a part of the Federal, State, and local tax clause in FAR 
52.229-1:

                      Sales or Use Taxes (Apr 1984)

    Any article purchased from this contract, payable from personal 
funds of patients, will be subject to any applicable sales or use tax 
levied thereon by any State, or by duly constituted taxing authority 
therein having jurisdiction to levy such a tax; the total amount of the 
tax applicable to such purchase payable from personal funds of patients 
will be computed on the total amount of the order and will be shown as a 
separate item on the purchase order and invoice. The bidder shall 
identify the applicable taxes and rates in his/her bid.

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan. 7, 1985]



852.233-70  Protest content.

    As prescribed in 833.106, insert the following provision in 
solicitations for other than small purchases:

                       Protest Content (June 1987)

    (a) Any protest filed by an interested party shall:
    (1) Include the name, address, and telephone number of the 
protester;

[[Page 236]]

    (2) Identify the solicitation and/or contract number;
    (3) Include an original signed by the protester or his/her 
representative, and at least one copy;
    (4) Set forth a detailed statement of the legal and factual ground 
of the protest including copies of relevant documents;
    (5) Specifically request a ruling of the individual upon whom the 
protest is served; and
    (6) State the form of relief requested.
    (b) Failure to comply with the above may result in dismissal of the 
protest without further consideration.

                           (End of Provision)

[52 FR 28561, July 31, 1987, as amended at 52 FR 49017, Dec. 29, 1987]



852.236-70  Clauses and provisions for fixed-price construction contracts.

    (a) The clauses and provisions prescribed in this section are set 
forth for use in fixed-price construction contracts in addition to those 
in FAR Subpart 52.2.
    (b) Additional clauses and provisions not inconsistent with those in 
FAR Subparts 36.5 and 52.2 and those prescribed in this subpart are 
authorized when determined necessary or desirable by the contracting 
officer, and when approved as provided in subpart 801.4.
    (c) Clauses and provisions inconsistent with those contained in FAR 
Subpart 36.5 and 52.2 and this subpart, but considered essential to the 
procurement of Department of Veterans Affairs requirements, shall not be 
used unless the deviation procedure set forth in subpart 801.4 has been 
complied with.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 796, Jan. 7, 1985]



852.236-71  Specifications and drawings for construction.

    The clause entitled ``Specifications and Drawings for 
Construction,'' in FAR 52.236-21 is supplemented as follows:

         Specifications and Drawings for Construction (Apr 1984)

    (a) The contracting officer's interpretation of the drawings and 
specifications will be final, subject to the disputes clause.
    (b) Large scale drawings supersede small scale drawings.
    (c) Dimensions govern in all cases. Scaling of drawings may be done 
only for general location and general size of items.
    (d) Dimensions shown of existing work and all dimensions required 
for work that is to connect with existing work, shall be verified by the 
contractor by actual measurement of the existing work. Any work at 
variance with that specified or shown in the drawings shall not be 
performed by the contractor until approved in writing by the contracting 
officer.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.236-72  Performance of work by the contractor.

    The clause entitled ``Performance of Work by the Contractor,'' in 
FAR 52.236-1, is supplemented as follows:

            Performance of Work by the Contractor (Apr 1984)

    (a) Contract work accomplished on the site by laborers, mechanics, 
and foremen/forewomen on the contractor's payroll and under his/her 
direct supervision shall be included in establishing the percent of work 
to be performed by the contractor. Cost of material and equipment 
installed by such labor may be included. The work by contractor's 
executive, supervisory and clerical forces shall be excluded in 
establishing compliance with the requirements of ths clause.
    (b) The contractor shall submit, simultaneously with schedule of 
costs required by Payments under Fixed-Price Construction Contract 
provision of the General Conditions of these specifications, a statement 
designating the branch or branches of contract work to be performed with 
his/her forces. The approved schedule of costs will be used in 
determining value of a branch or branches, or portions therof, of the 
work for the purpose of this article.
    (c) If, during the progress of work hereunder, the contractor 
requests a change in the branch or branches of the work to be performed 
by his/her forces and the contracting officer determines it to be in the 
best interests of the Government, the contracting officer may, at his/
her discretion, authorize a change in such branch or branches of said 
work. Nothing contained herein shall permit a reduction in the 
percentage of work to be performed by the contractor with his/her 
forces, it being expressly understood that this is a contract 
requirement without right or privilege of reduction.
    (d) In the event the contractor fails or refuses to meet the 
requirement of paragraph (a) of this clause, it is expressly agreed that

[[Page 237]]

the contract price will be reduced by 15 percent of the value of that 
portion of the percentage requirement which is accomplished by others. 
For the purposes of this clause, it is agreed that 15 percent is an 
acceptable estimate of the contractor's overhead and profit, or mark-up, 
on that portion of the work which the contractor fails or refuses to 
perform, with his/her own forces, in accordance with paragraph (a) of 
this clause.

                             (End of clause)

                         Alternate I (Jan. 1988)

    For requirements which include Network Analysis System (NAS), 
substitute the following paragraphs (b) and (c) for paragraphs (b) and 
(c) of the basic clause:
    (b) The contractor shall submit, simultaneously with the cost per 
activity of the construction schedule required by Section 01311, NETWORK 
ANALYSIS SYSTEM, a responsibility code for all activities of the network 
for which the contractor's forces will perform the work. The cost of 
these activities will be used in determining the portions of the total 
contract work to be executed by the contractor's forces for the purpose 
of this article.
    (c) If, during progress of work hereunder, the contractor requests a 
change in activities of work to be performed by contractor's forces and 
the contracting officer determines it to be in the best interest of the 
Government, the contracting officer may, at contracting officers' 
discretion, authorize a change in such activities of said work.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 796, Jan. 7, 1985; 
53 FR 1631, Jan. 21, 1988; 53 FR 2669, Jan. 29, 1988]



852.236-73  Bonds.

                            Bonds (Nov 1984)

    For contracts in excess of $25,000, the contractor must furnish a 
Performance Bond (Standard Form 25) for 100 percent of the amount of the 
contract, and a Payment Bond (Standard Form 25-A) in the penal sums set 
forth below:

                                                                        
------------------------------------------------------------------------
            Amount of contract                    Penal sum of bond     
------------------------------------------------------------------------
$25,000 to $1,000,000.....................  Fifty (50) percent of the   
                                             amount of the contract.    
$1,000,001 to $5,000,000..................  Forty (40) percent of the   
                                             amount of the contract.    
$5,000,001 and over.......................  $2,500,000.                 
------------------------------------------------------------------------

    When net changes in original contract price affect the premium of a 
Corporate Surety Bond by $5 or more, the Government in determining basis 
for final settlement, will provide for bond premium adjustment computed 
at the rate shown in the bond.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 797, Jan. 7, 1985]



852.236-74  Inspection of construction.

    The clause entitled, ``Inspection of Construction,'' in FAR 52.246-
12, is supplemented as follows:

                  Inspection of Construction (Apr 1984)

    (a) Inspection of materials and articles furnished under this 
contract will be made at the site by the resident engineer, unless 
otherwise provided for in the specifications.
    (b) Final inspection will not be made until the contract work is 
ready for beneficial use or occupancy. The contractor shall notify the 
contracting officer, through the resident engineer, fifteen (15) days 
prior to the date on which the work will be ready for final inspection.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.236-75  Guaranty.

                           Guaranty (Apr 1984)

    (a) Unless otherwise specifically provided for in the contract or 
specifications, the contractor, notwithstanding any final inspection, 
acceptance or payment, guarantees that all work performed and materials 
and equipment furnished under this contract are in accordance with the 
contract requirements. The contractor also guarantees that when 
installed all materials and equipment will be free from defects and will 
remain so for a period of at least one year from the date of acceptance 
by the Government.
    (b) If defects of any kind should develop during the period such 
guarantees are in force, the contracting officer shall immediately 
notify the contractor in writing of such defects. The Government 
thereupon shall have the right, by a written notice to that effect, to 
require the contractor to repair or replace all inferior or defective 
work, material, or equipment or permit it to remain in place and assess 
the contractor the costs he/she (the contractor) would have incurred had 
he/she been required to effect repair or replacement.
    (c) Any correction or replacement of parts, materials, equipment, 
supplies or construction made pursuant to the provisions of this clause 
shall also be subject to the provisions of this clause to the same 
extent as parts, materials, equipment, supplies or construction 
originally installed. The warranty with respect to such new or corrected 
parts, materials, equipment, supplies or construction shall be equal in 
duration as that set forth in

[[Page 238]]

(a) above and shall run from the date that such parts, materials, 
equipment, supplies or construction are replaced or corrected and 
accepted by the Government.
    (d) The contractor guarantees to reimburse the Government for, or to 
repair or replace, any damages to the site, buildings, or contents 
thereof that are caused by inferior or defective workmanship, or the use 
of inferior or defective materials or equipment in the performance of 
this contract. The contracting officer shall immediately notify the 
contractor in writing when such damage occurs. The Government shall have 
the right to require the contractor to repair or replace such damaged 
areas or equipment, or elect to permit such damage to remain as is and 
assess the contractor the costs he/she would have incurred had he/she 
been required to effect repair or replacement.
    (e) Should the contractor fail to proceed promptly, after 
notification by the contracting officer, to repair or replace any 
inferior or defective work, material, or equipment, or damage to the 
site, buildings, or contents, thereof, caused by inferior or defective 
work, or the use of inferior or defective materials, or equipment, the 
Government may have such work, material, equipment or damage repaired or 
replaced and charge all costs incident thereto to the contractor.
    (f) Any special guaranties that may be required under the contract, 
shall be subject to the elections set forth above unless otherwise 
provided in such special guaranties.
    (g) The decision of the contracting officer as to liability of the 
contractor under this clause is subject to the appeal procedures 
provided for in the disputes clause of this contract.

                             (End of clause)

                        Supplement I (Jan. 1988)

    If the specifications include guarantee period services, add the 
following paragraph (g) and redesignate paragraph (g) in the basic text 
as paragraph (h).
    (g) Should the contractor fail to prosecute the work or fail to 
proceed promptly to provide guarantee period services after notification 
by the contracting officer, the Government may, subject to the default 
clause contained at FAR section 52.249-10, Default (Fixed-Price 
Construction), and after allowing the contractor 10 days to correct and 
comply with the contract, terminate the right to proceed with the work 
(or the separable part of the work) that has been delayed or 
unsatisfactorily performed. In this event, the Government may take over 
the work and complete it by contract or otherwise, and may take 
possession of and use any materials, appliance, and plant on the work 
site necessary for completing the work. The contractor and its sureties 
shall be liable for any damages to the Government resulting from the 
contractor's refusal or failure to complete the work within this 
specified time, whether or not the contractor's right to proceed with 
the work is terminated. This liability includes any increased costs 
incurred by the Government in completing the work.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 53 
FR 1631, Jan. 21, 1988; 53 FR 2669, Jan. 29, 1988]



852.236-76  Correspondence.

                        Correspondence (Apr 1984)

    All correspondence relative to this contract shall bear 
Specification Number, Project Number, Department of Veterans Affairs 
Contract Number, title of project and name of facility.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985; 54 
FR 40066, Sept. 29, 1989]



852.236-77  Reference to ``standards.''

                          Standards (Apr 1984)

    Any materials, equipment, or workmanship specified by references to 
number, symbol, or title of any specific Federal, Industry or Government 
Agency Standard Specification shall comply with all applicable 
provisions of such standard specifications, except as limited to type, 
class or grade, or modified in contract specifications. Reference to 
``Standards'' referred to in the contract specifications, except as 
modified, shall have full force and effect as though printed in detail 
in specifications.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 797, Jan. 7, 1985]



852.236-78  Government supervision.

                    Government Supervision (Apr 1984)

    (a) The work will be under the direction of the Department of 
Veterans Affairs contracting officer, who may designate another VA 
employee to act as resident engineer at the construction site.
    (b) Except as provided below, the resident engineer's directions 
will not conflict with or change contract requirements.
    (c) Within the limits of any specific authority delegated by the 
contracting officer, the resident engineer may by written direction make 
changes in the work. The contractor shall be advised of the extent of 
such authority prior to execution of any work under the contract.

[[Page 239]]

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.236-79  Daily report of workers and materials.

             Daily Report of Workers and Material (Apr 1984)

    The contractor shall furnish to the resident engineer each day a 
consolidated report for the preceding work day in which is shown the 
number of laborers, mechanics, foremen/forewomen and pieces of heavy 
equipment used or employed by the contractor and subcontractors. The 
report shall bear the name of the firm, the branch of work which they 
perform such as concrete, plastering, masonry, plumbing, sheet metal 
work, etc. The report shall give a breakdown of employees by crafts, 
location where employed, and work performed. The report shall also list 
materials delivered to the site on the date covered by the report.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.236-80  Subcontracts and work coordination.

    The following clause is for use except as provided in 852.236-81:

              Subcontracts and Work Coordination (Apr 1984)

    (a) Nothing contained in this contract shall be construed as 
creating any contractual relationship between any subcontractor and the 
Government. Divisions or sections of specifications are not intended to 
control the contractor in dividing work among subcontractors, or to 
limit work performed by any trade.
    (b) The contractor shall be responsible to the Government for acts 
and omissions of his/her own employees, and of the subcontractors and 
their employees. The contractor shall also be responsible for 
coordination of the work of the trades, subcontractors, and material 
suppliers.
    (c) The Government or its representatives will not undertake to 
settle any differences between the contractor and subcontractors or 
between subcontractors.
    (d) The Government reserves the right to refuse to permit employment 
on the work or require dismissal from the work of any subcontractor who, 
by reason of previous unsatisfactory work on Department of Veterans 
Affairs projects or for any other reason, is considered by the 
contracting officer to be incompetent or otherwise objectionable.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.236-81  Work coordination (alternate provision).

    For new construction work with complex mechanical-electrical work, 
the following clause relating to work coordination may be substituted 
for paragraph (b) of the clause set forth in 852.236-80:

                      Work Coordination (Apr 1984)

    The contractor shall be responsible to the Government for acts and 
omissions of his/her own employees, and subcontractors and their 
employees. The contractor shall also be responsible for coordination of 
the work of the trades, subcontractors, and material suppliers. The 
contractor shall, in advance of the work, prepare coordination drawings 
showing the location of openings through slabs, the pipe sleeves and 
hanger inserts, as well as the location and elevation of utility lines, 
including, but not limited to, conveyor systems, pneumatic tubes, ducts, 
and conduits and pipes 2 inches and larger in diameter. These drawings, 
including plans, elevations, and sections as appropriate shall clearly 
show the manner in which the utilities fit into the available space and 
relate to each other and to existing building elements. Drawings shall 
be of appropriate scale to satisfy the previously stated purposes, but 
not smaller than \3/8\-inch scale. Drawings may be composite (with 
distinctive colors for the various trades) or may be separate but fully 
coordinated drawings (such as sepias or photographic paper 
reproducibles) of the same scale. Separate drawings shall depict 
identical building areas or sections and shall be capable of being 
overlaid in any combination. The submitted drawings for a given area of 
the project shall show the work of all trades which will be involved in 
that particular area. Six complete composite drawings or six complete 
sets of separate reproducible drawings shall be received by the 
Government not less than 20 days prior to the scheduled start of the 
work in the area illustrated by the drawings, for the purpose of showing 
the contractor's planned methods of installation. The objectives of such 
drawings are to promote carefully planned work sequence and proper trade 
coordination, in order to assure the expeditious solutions of problems 
and the installation of lines and equipment as contemplated by the 
contract documents while avoiding or minimizing additional costs to the 
contractor and to the Government. In the event the contractor, in 
coordinating the various installations and in planning the method of 
installation, finds a

[[Page 240]]

conflict in location or elevation of any of the utilities with 
themselves, with structural items or with other construction items, he/
she shall bring this conflict to the attention of the contracting 
officer immediately. In doing so, the contractor shall explain the 
proposed method of solving the problem or shall request instructions as 
to how to proceed if adjustments beyond those of usual trades 
coordination are necessary. Utilities installation work will not proceed 
in any area prior to the submission and completion of the Government 
review of the coordinated drawings for that area, nor in any area in 
which conflicts are disclosed by the coordination drawings until the 
conflicts have been corrected to the satisfaction of the contracting 
officer. It is the responsibility of the contractor to submit the 
required drawings in a timely manner consistent with the requirements to 
complete the work covered by this contract within the prescribed 
contract time.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 797, Jan. 7, 1985; 
53 FR 1632, Jan. 21, 1988]



852.236-82  Payments under fixed-price construction contracts (without NAS).

    For contracts that do not contain a section entitled ``Network 
Analysis System (NAS),'' the clause entitled ``Payments under Fixed-
Price Construction Contracts'' in FAR 52.232-5 will be supplemented as 
follows:

      Payments Under Fixed-Price Construction Contracts (Apr 1984)

    The clause entitled ``Payments Under Fixed-Price Construction 
Contracts'' in FAR 52.232-5 is implemented as follows:
    (a) Retainage:
    (1) The contracting officer may retain funds:
    (i) Where performance under the contract has been determined to be 
deficient or the contractor has performed in an unsatisfactory manner in 
the past; or
    (ii) As the contract nears completion, to ensure that deficiencies 
will be corrected and that completion is timely.
    (2) Examples of deficient performance justifying a retention of 
funds include, but are not restricted to, the following:
    (i) Unsatisfactory progress as determined by the contracting 
officer;
    (ii) Failure to meet schedule in Schedule of Work Progress;
    (iii) Failure to present submittals in a timely manner; or
    (iv) Failure to comply in good faith with approved subcontracting 
plans, certifications or contract requirements.
    (3) Any level of retention shall not exceed 10 percent either where 
there is determined to be unsatisfactory performance, or when the 
retainage is to ensure satisfactory completion. Retained amounts shall 
be paid promptly upon completion of all contract requirements, but 
nothing contained in this subparagraph shall be construed as limiting 
the contracting officer's right to withhold funds under other provisions 
of the contract or in accordance with the general law and regulations 
regarding the administration of Government contracts.
    (b) The contractor shall submit a schedule of cost to the 
contracting officer for approval within 30 calendar days after date of 
receipt of notice to proceed. Such schedule will be signed and submitted 
in triplicate. The approved cost schedule will be one of the bases for 
determining progress payments to the contractor for work completed. This 
schedule shall show cost by the branches of work for each building or 
unit of the contract, as instructed by the resident engineer.
    (1) The branches shall be subdivided into as many subbranches as are 
necessary to cover all component parts of the contract work.
    (2) Costs as shown on this schedule must be true costs and, should 
the resident engineer so desire he/she may require the contractor to 
submit the original estimate sheets or other information to substantiate 
detailed makeup of schedule.
    (3) The sum of subbranches, as applied to each branch, shall equal 
the total cost of such branch. The total costs of all branches shall 
equal the contract price.
    (4) Insurance and similar items shall be prorated and included in 
the cost of each branch of the work.
    (5) The cost schedule shall include separate cost information for 
the systems listed below. The percentages listed below are proportions 
of the cost listed in contractor's cost schedule and identify, for 
payment purposes, the value of the work to adjust, correct and test 
systems after the material has been installed. Payment of the listed 
percentages will be made only after the contractor has demonstrated that 
each of the systems is substantially complete and operates as required 
by the contract.

           Value of Adjusting, Correcting, and Testing System           
------------------------------------------------------------------------
                            System                              Percent 
------------------------------------------------------------------------
Pneumatic tube system........................................         10
Incinerators (medical waste and trash).......................          5
Sewage treatment plant equipment.............................          5
Water treatment plant equipment..............................          5
Washers (dish, cage, glass, etc.)............................          5
Sterilizing equipment........................................          5
Water distilling equipment...................................          5

[[Page 241]]

                                                                        
Prefab temperature rooms (cold, constant temperature)........          5
Entire air-conditioning system (Specified under 600 Sections)          5
Entire boiler plant system (Specified under 700 Sections)....          5
General supply conveyors.....................................         10
Food service conveyors.......................................         10
Pneumatic soiled linen and trash system......................         10
Elevators and dumbwaiters....................................         10
Materials transport system...................................         10
Engine-generator system......................................          5
Primary switchgear...........................................          5
Secondary switchgear.........................................          5
Fire alarm system............................................          5
Nurse call system............................................          5
Intercom system..............................................          5
Radio system.................................................          5
TV (entertainment) system....................................          5
------------------------------------------------------------------------

    (c) In addition to this cost schedule, the contractor shall submit 
such unit costs as may be specifically requested. The unit costs shall 
be those used by the contractor in preparing his/her bid and will not be 
binding as pertaining to any contract changes.
    (d) The contracting officer will consider for monthly progress 
payments material and/or equipment procured by the contractor and stored 
on the construction site as space is available, or at a local approved 
location off the site, under such terms and conditions as such officer 
approves, including but not limited to the following:
    (1) The material or equipment is in accordance with the contract 
requirements and/or approved samples and shop drawings.
    (2) Only those materials and/or equipment as are approved by the 
resident engineer for storage will be included.
    (3) Such materials and/or equipment will be stored separately and 
will be readily available for inspection and inventory by the resident 
engineer.
    (4) Such materials and/or equipment will be protected against 
weather, theft and other hazards and will not be subjected to 
deterioration.
    (5) All of the other terms, provisions, conditions and covenants 
contained in the contract shall be and remain in full force and effect 
as therein provided.
    (6) A supplemental agreement will be executed between the Government 
and the contractor with the consent of the contractor's surety for off-
site storage.
    (e) The contractor, prior to receiving a progress or final payment 
under this contract, shall submit to the contracting officer a 
certification that the contractor has made payment from proceeds of 
prior payments, or that timely payment will be made from the proceeds of 
the progress or final payment then due, to subcontractors and suppliers 
in accordance with the contractual arrangements with them.
    (f) The Government reserves the right to withhold payment until 
samples, shop drawings, engineer's certificates, additional bonds, 
payrolls, weekly statements of compliance, proof of title, 
nondiscrimination compliance reports, or any other things required by 
this contract, have been submitted to the satisfaction of the 
contracting officer.

                             (End of clause)

                        Supplement I (Jan. 1988)

    If the specifications include guarantee period services, include the 
following paragraphs (6) (i) and (ii) as an addition to the basic clause 
in paragraph (b):
    (6)(i) The contractor shall at the time of contract award furnish 
the total cost of the guarantee period services in accordance with 
specification section(s) covering guarantee period services. The 
contractor shall submit, within 15 calendar days of notice to proceed, 
the guarantee period performance program which shall include an itemized 
accounting of the number of workhours required to perform the guarantee 
period service on each piece of equipment. The contractor shall also 
submit the estimated costs including employee fringe benefits and what 
the contractor reasonably expects to pay over the guarantee period 
service, all of which will be subject to the contracting officer's 
approval.
    (ii) The cost of the guarantee service shall be prorated on an 
annual basis and paid in equal monthly payments by VA during the period 
of guarantee. In the event the installer does not perform satisfactorily 
during this period, all payments may be withheld, and the contracting 
officer shall inform the contractor of the unsatisfactory performance, 
allowing the contractor 10 days to correct deficiencies and comply with 
the contract. The guarantee period service is subject to those 
provisions as set forth in the Payment and Default clauses.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 797, Jan. 7, 1985; 
53 FR 1632, Jan. 21, 1988; 54 FR 40066, Sept. 29, 1989]



852.236-83  Payments under fixed-price construction contracts (including NAS).

    For contracts that contain a section entitled ``Network Analysis 
System (NAS),'' the clause entitled ``Payments under Fixed-Price 
Construction Contracts'' in FAR 52.232-5 is supplemented as follows:

[[Page 242]]

      Payments Under Fixed-Price Construction Contracts (Apr 1984)

    The clause entitled ``Payments under Fixed-Price Construction 
Contracts in FAR 52.232-5 is implemented as follows:
    (a) Retainage:
    (1) The contracting officer may retain funds:
    (i) Where performance under the contract has been determined to be 
deficient or the contractor has performed in an unsatisfactory manner in 
the past; or
    (ii) As the contract nears completion, to ensure that deficiencies 
will be corrected and that completion is timely.
    (2) Examples of deficient performance justifying a retention of 
funds include, but are not restricted to, the following:
    (i) Unsatisfactory progress as determined by the contracting 
officer;
    (ii) Failure either to meet schedules in Section Network Analysis 
System (NAS), or to process the Interim Arrow Diagram/Complete Project 
Arrow Diagram;
    (iii) Failure to present submittals in a timely manner; or
    (iv) Failure to comply in good faith with approved subcontracting 
plans, certifications or contract requirements.
    (3) Any level of retention shall not exceed 10 percent either where 
there is determined to be unsatisfactory performance, or when the 
retainage is to ensure satisfactory completion. Retained amounts shall 
be paid promptly upon completion of all contract requirements, but 
nothing contained in this subparagraph shall be construed as limiting 
the contracting officer's right to withhold funds under other provisions 
of the contract or in accordance with the general law and regulations 
regarding the administration of Government contracts.
    (b) The contractor shall submit a schedule of costs in accordance 
with the requirements of Section Network Analysis System (NAS) to the 
contracting officer for approval within 90 calendar days after date of 
receipt of notice to proceed. The approved cost schedule will be one of 
the bases for determining progress payments to the contractor for work 
completed.
    (1) Costs as shown on this schedule must be true costs and, should 
the resident engineer so desire, he/she may require the contractor to 
submit his/her original estimate sheets or other information to 
substantiate the detailed makeup of the cost schedule.
    (2) The total costs of all activities shall equal the contract 
price.
    (3) Insurance and similar items shall be prorated and included in 
each activity cost of the critical path method (CPM) network.
    (4) The CPM network shall include a separate cost loaded activity 
for adjusting and testing of the systems listed below. The percentages 
listed below will be used to determine the cost of adjust and test 
activities and identify, for payment purposes, the value of the work to 
adjust, correct and test systems after the material has been installed.
    (5) Payment for adjust and test activities will be made only after 
the contractor has demonstrated that each of the systems is 
substantially complete and operates as required by the contract.

           Values of Adjusting Correcting, and Testing System           
------------------------------------------------------------------------
                            System                              Percent 
------------------------------------------------------------------------
Pneumatic tube system........................................         10
Incinerators (medical waste and trash).......................          5
Sewage treatment plant equipment.............................          5
Water treatment plant equipment..............................          5
Washers (dish, cage, glass, etc.)............................          5
Sterilizing equipment........................................          5
Water distilling equipment...................................          5
Prefab temperature rooms (cold, constant temperature)........          5
Entire air-conditioning system (Specified under 600 Sections)          5
Entire boiler plant system (specified under 700 Sections)....          5
General supply conveyors.....................................         10
Food service conveyors.......................................         10
Pneumatic soiled linen and trash system......................         10
Elevators and dumbwaiters....................................         10
Materials transport system...................................         10
Engine-generator system......................................          5
Primary switchgear...........................................          5
Secondary switchgear.........................................          5
Fire alarm system............................................          5
Nurse call system............................................          5
Intercom system..............................................          5
Radio system.................................................          5
TV (entertainment) system....................................          5
------------------------------------------------------------------------

    (c) In addition to this cost schedule, the contractor shall submit 
such unit costs as may be specifically requested. The unit costs shall 
be those used by the contractor in preparing the bid and will not be 
binding as pertaining to any contract changes.
    (d) The contracting officer will consider for monthly progress 
payments material and/or equipment procured by the contractor and stored 
on the construction site as space is available, or at a local approved 
location off the site, under such terms and conditions as such officer 
approves, including but not limited to the following:
    (1) The material or equipment is in accordance with the contract 
requirements and/or approved samples and shop drawings.
    (2) Only those materials and/or equipment as are approved by the 
resident engineer for storage will be included.
    (3) Such materials and/or equipment will be stored separately and 
will be readily available for inspection and inventory by the resident 
engineer.
    (4) Such materials and/or equipment will be protected against 
weather, theft and other hazards and will not be subjected to 
deterioration.

[[Page 243]]

    (5) All of the other terms, provisions, conditions and covenants 
contained in the contract shall be and remain in full force and effect 
as therein provided.
    (6) A supplemental agreement will be executed between the Government 
and the contractor with the consent of the contractor's surety for off-
site storage.
    (e) The contractor, prior to receiving a progress or final payment 
under this contract, shall submit to the contracting officer a 
certification that the contractor has made payment from proceeds of 
prior payments, or that timely payment will be made from the proceeds of 
the progress or final payment then due, to subcontractors and suppliers 
in accordance with the contractual arrangements with them.
    (f) The Government reserves the right to withhold payment until 
samples, shop drawings, engineer's certificates, additional bonds, 
payrolls, weekly statements of compliance, proof of title, 
nondiscrimination compliance reports, or any other things required by 
this contract, have been submitted to the satisfaction of the 
contracting officer.

                             (End of clause)

                         Supplement I (Jan 1988)

    If the specifications include guarantee period services, include the 
following paragraphs (6) (i), (ii), and (iii) as an addition to the 
basic clause in paragraph (b):
    (6)(i) The contractor shall show on the critical path method (CPM) 
network the total cost of the guarantee period services in accordance 
with the guarantee period service section(s) of the specifications. This 
cost shall be priced out when submitting the CPM cost loaded network. 
The cost submitted shall be subject to the approval of the contracting 
officer. The activity on the CPM shall have money only and not activity 
time.
    (ii) The contractor shall submit with the CPM a guarantee period 
performance program which shall include an itemized accounting of the 
number of workhours required to perform the guarantee period service on 
each piece of equipment. The contractor shall also submit the 
established costs including employee fringe benefits and what the 
contractor reasonably expects to pay over the guarantee period service, 
all of which will be subject to the contracting officer's approval.
    (iii) The cost of the guarantee period service shall be prorated on 
an annual basis and paid in equal monthly payments by VA during the 
period of guarantee. In the event the installer does not perform 
satisfactorily during this period, all payments may be withheld and the 
contracting officer shall inform the contractor of the unsatisfactory 
performance allowing the contractor 10 days to correct and comply with 
the contract. The guarantee period service is subject to those 
provisions as set forth in the Payment and Default clauses.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 797, Jan. 7, 1985; 
53 FR 1632, Jan. 21, 1988; 54 FR 40066, Sept. 29, 1989; 61 FR 11587, 
Mar. 21, 1996]



852.236-84  Schedule of work progress.

    This clause is to be used on projects which do not include a section 
entitled ``Network Analysis System (NAS).'' The cost-loaded activity 
network serves the same general purpose as the schedule of work 
progress.

                  Schedule of Work Progress (Nov 1984)

    (a) The contractor shall submit with the schedule of costs, a 
progress schedule that indicates the anticipated installation of work 
versus the elapsed contract time, for the approval of the contracting 
officer. The progress schedule time shall be represented in the form of 
a bar graph with the contract time plotted along the horizontal axis. 
The starting date of the schedule shall be the date the contractor 
receives the ``Notice to Proceed.'' The ending date shall be the 
original contract completion date. At a minimum, both dates shall be 
indicated on the progress schedule. The specific item of work, i.e., 
``Excavation'', ``Floor Tile'', ``Finish Carpentry'', etc., should be 
plotted along the vertical axis and indicated by a line or bar at which 
time(s) during the contract this work is scheduled to take place. The 
schedule shall be submitted in triplicate and signed by the contractor.
    (b) The actual percent completion will be based on the value of 
installed work divided by the current contract amount. The actual 
completion percentage will be indicated on the monthly progress report.
    (c) The progress schedule will be revised when individual or 
cumulative time extensions of 15 calendar days or more are granted for 
any reason. The revised schedule should indicate the new contract 
completion date and should reflect any changes to the installation 
time(s) of the items of work affected.
    (d) The revised progress schedule will be used for reporting future 
scheduled percentage completion.

                             (End of clause)

[50 FR 794, 797, Jan. 7, 1985, as amended at 53 FR 1632, Jan. 21, 1988]



852.236-85  Supplementary labor standards provisions.

           Supplementary Labor Standards Provisions (Apr 1984)

    (a) The wage determination decision of the Secretary of Labor is set 
forth in section GR,

[[Page 244]]

General Requirements, of this contract. It is the result of a study of 
wage conditions in the locality and establishes the minimum hourly rates 
of wages and fringe benefits for the described classes of labor in 
accordance with applicable law. No increase in the contract price will 
be allowed or authorized because of payment of wage rates in excess of 
those listed.
    (b) The contractor shall submit the required copies of payrolls to 
the contracting officer through the resident engineer or engineer 
officer, when acting in that capacity. Department of Labor Form WH-347, 
Payroll, available from the Superintendent of Documents, Government 
Printing Office, Washington, DC 20402, may be used for this purpose. If, 
however, the contractor or subcontractor elects to use an individually 
composed payroll form, it shall contain the same information shown on 
Form WH-347, and in addition be accompanied by Department of Labor Form 
WH-348, Statement of Compliance, or any other form containing the exact 
wording of this form.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.236-86  Workmen's compensation.

                    Workmen's Compensation (Apr 1984)

    The Act of June 25, 1936, 49 Stat. 1938 (40 U.S.C. 290) authorizes 
the constituted authority of the several states to apply their workmen's 
compensation laws to all lands and premises owned or held by the United 
States.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.236-87  Accident prevention.

    As prescribed in 836.513, insert the following clause:

                  Accident Prevention (September 1993)

    The Resident Engineer on all assigned construction projects, or 
other Department of Veterans Affairs employee if designated in writing 
by the Contracting Officer, shall serve as Safety Officer and as such 
has authority, on behalf of the Contracting Officer, to monitor and 
enforce Contractor compliance with FAR 52.236-13, Accident Prevention. 
However, only the Contracting Officer may issue an order to stop all or 
part of the work while requiring satisfactory or corrective action to be 
taken by the Contractor.

                             (End of clause)

[58 FR 48974, Sept. 21, 1993]



852.236-88  Contract changes.

    The clauses, entitled ``Changes'' in FAR 52.243-4 and ``Differing 
Site Conditions'' in FAR 52.236-2 will be supplemented with the 
following two clauses. Both clauses shall be included in the 
contract.The clause in paragraph (a) of this section will apply to 
negotiated changes exceeding $500,000 and does not provide ceiling rates 
for indirect expenses. Such expenses will be included as part of the 
submission of certified cost and pricing data, will be negotiated by the 
contracting officer and will be audited in accordance with 815.505-5. 
When the negotiated change will be less than $500,000 the clause 
specified in paragraph (b) of this section will apply. Proposals over 
$100,000 and not exceeding $500,000 shall be accompanied by certificates 
of current cost or pricing data. If cost and pricing data are required 
for proposals of $100,000 or less, the contracting officer may require 
that it be certified in accordance with FAR 15.804-2(a)(2). It must be 
emphasized that the indirect cost rates are ceiling rates only, and the 
contracting officer will negotiate the indirect expense rates within the 
ceiling limitations. The clauses are a result of an approved FAR 
deviation pursuant to subpart 801.4.
    (a) Applicable to changes costing over $500,000:

   Changes--Supplement (For Changes Costing Over $500,000) (June 1987)

    The clauses entitled ``Changes'' in FAR 52.243-4 and ``Differing 
Site Conditions'' in FAR 52.236-2 are supplemented as follows:
    (a) When requested by the contracting officer, the contractor shall 
submit proposals for changes in work to the resident engineer. 
Proposals, to be submitted within 30 calendar days after receipt of 
request, shall be in legible form, original and two copies, with an 
itemized breakdown that will include material, quantities, unit prices, 
labor costs (separated into trades), construction equipment, etc. (Labor 
costs are to be identified with specific material placed or operation 
performed.) The contractor must obtain and furnish with a proposal an 
itemized breakdown as described above, signed by each subcontractor 
participating in the change regardless of tier. When certified cost or 
pricing data are required under FAR Subpart

[[Page 245]]

15.804, the cost or pricing data shall be submitted on Standard Form 
1411 (SF 1411), Contract Pricing Proposal Cover Sheet, in accordance 
with FAR 15.804-6.
    (b) When the necessity to proceed with a change does not allow 
sufficient time to negotiate a modification or because of failure to 
reach an agreement, the contracting officer may issue a change order 
instructing the contractor to proceed on the basis of a tentative price 
based on the best estimate available at the time, with the firm price to 
be determined later. Furthermore, when the change order is issued, the 
contractor shall submit a proposal for cost of changes in work within 30 
calendar days.
    (c) The contracting officer will consider issuing a settlement by 
determination to the contract, if the contractor's proposal required by 
paragraphs (a) and (b) of this clause is not received within 30 calendar 
days, or if agreement has not been reached.
    (d) Bond premium adjustment, consequent upon changes ordered, will 
be made as elsewhere specified at the time of final settlement under the 
contract and will not be included in the individual change.

                             (End of clause)

    (b) Applicable to changes costing $500,000 or less:

 Changes--Supplement (For Changes Costing $500,000 or Less) (June 1987)

    The clauses entitled ``Changes'' in FAR 52.243-4 and ``Differing 
Site Conditions'' in FAR 52.236-2 are supplemented as follows:
    (a) When requested by the contracting officer, the contractor shall 
submit proposals for changes in work to the resident engineer. 
Proposals, to be submitted within 30 calendar days after receipt of 
request, shall be in legible form, original and two copies, with an 
itemized breakdown that will include material, quantities, unit prices, 
labor costs (separated into trades), construction equipment, etc. (Labor 
costs are to be identified with specific material placed or operation 
performed.) The contractor must obtain and furnish with a proposal an 
intemized breakdown as described above, signed by each subcontractor 
participating in the change regardless of tier. When certified cost or 
pricing data are required under FAR 15.804 for proposals over $100,000, 
the cost of pricing data shall be submitted on SF 1411, Contract Pricing 
Proposal Cover Sheet, in accordance with FAR 15.804-6. No itemized 
breakdown will be required for proposals amounting to less than $1,000.
    (b) When the necessity to proceed with a change does not allow 
sufficient time to negotiate a modification or because of failure to 
reach an agreement, the contracting officer may issue a change order 
instructing the contractor to proceed on the basis of a tentative price 
based on the best estimate available at the time, with the firm price to 
be determined later. Furthermore, when the change order is issued, the 
contractor shall submit a proposal for cost of changes in work within 30 
calendar days.
    (c) The contracting officer will consider issuing a settlement by 
determination to the contract, if the contractor's proposal required by 
paragraphs (a) and (b) of this clause is not received within 30 calendar 
days, or if agreement has not been reached.
    (d) Allowances not to exceed 10 percent each for overhead and profit 
for the party performing the work will be based on the value of labor, 
material, and use of construction equipment required to accomplish the 
change. As the value of the change increases, a declining scale will be 
used in negotiating the percentage of overhead and profit. Allowable 
percentages on changes will not exceed the following: 10 percent 
overhead and 10 percent profit on the first $20,000; 7\1/2\ percent 
overhead and 7\1/2\ percent profit on the next $30,000; 5 percent 
overhead and 5 percent profit on balance over $50,000. Profit shall be 
computed by multiplying the profit percentage by the sum of the direct 
costs and computed overhead costs.
    (e) The prime contractor's or upper-tier subcontractor's fee on work 
performed by lower-tier subcontractors will be based on the net 
increased cost to the prime contractor or upper-tier subcontractor, as 
applicable. Allowable fee on changes will not exceed the following: 10 
percent fee on the first $20,000; 7\1/2\ percent fee on the next 
$30,000; and 5 percent fee on balance over $50,000.
    (f) Not more than four percentages, none of which exceed the 
percentages shown above, will be allowed regardless of the number of 
tiers of subcontractors.
    (g) Where the contractor's or subcontractors' portion of a change 
involves credit items, such items must be deducted prior to adding 
overhead and profit for the party performing the work. The contractor's 
fee is limited to the net increase to contractor of subcontractors' 
portions cost computed in accordance herewith.
    (h) Where a change involves credit items only, a proper measure of 
the amount of downward adjustment in the contract price is the 
reasonable cost to the contractor if he/she had performed the deleted 
work. A reasonable allowance for overhead and profit are properly 
includable as part of the downward adjustment for a deductive change. 
The amount of such allowance is subject to negotiation.
    (i) Cost of Federal Old Age Benefit (Social Security) tax and of 
Workmen's Compensation and Public Liability insurance appertaining to 
changes are allowable. While no percentage will be allowed thereon for 
overhead or profit, prime contractor's fee will be

[[Page 246]]

allowed on such items in subcontractor's proposals.
    (j) Overhead and contractor's fee percentages shall be considered to 
include insurance other than mentioned herein, field and office 
supervisors and assistants, security police, use of small tools, 
incidental job burdens, and general home office expenses and no separate 
allowance will be made therefor. Assistants to office supervisors 
include all clerical, stenographic and general office help. Incidental 
job burdens include, but are not necessarily limited to, office 
equipment and supplies, temporary toilets, telephone and conformance to 
OSHA requirements. Items such as, but not necessarily limited to, review 
and coordination, estimating and expediting relative to contract changes 
are associated with field and office supervision and are considered to 
be included in the contractor's overhead and/or fee percentage.
    (k) Bond premium adjustment, consequent upon changes ordered, will 
be made as elsewhere specified at the time of final settlement under the 
contract and will not be included in the individual change.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 797, Jan. 7, 1985; 
51 FR 23073, June 25, 1986; 52 FR 28559, 28561, July 31, 1987; 52 FR 
32013, Aug. 25, 1987; 52 FR 49017, Dec. 29, 1987; 53 FR 1632, Jan. 21, 
1988; 61 FR 11587, Mar. 21, 1996]



852.236-89  Buy American Act.

    The Buy American Act (41 U.S.C. 10a-d) requires that only domestic 
construction material shall be used in the performance of contracts for 
construction. To clarify VA's position on foreign material, the 
following ``Special Notice'' will be inserted into the bid package, in 
front of SF 20, Invitation for Bids:

                       Buy American Act (Nov 1984)

    (a) Reference is made to the clause entitled ``Buy American 
Construction Materials,'' FAR 52.225-5.
    (b) Notwithstanding a bidder's right to offer identifiable foreign 
material in its bid pursuant to the above provisions, VA does not 
anticipate accepting an offer that includes foreign items.
    (c) If a bidder chooses to submit a bid which includes foreign 
materials, that bidder must provide a listing of the specific foreign 
materials he/she intends to use and a price for said materials. Because 
VA has a strong preference for domestic items, bidders are strongly 
urged to include bid prices for comparable domestic construction 
material. If VA determines not to accept foreign items and no comparable 
domestic items are provided the entire bid will be rejected.
    (d) Any foreign item proposed after award will be rejected unless 
the bidder proves to VA's satisfaction: (1) it was impossible to request 
the exemption prior to award, and (2) said domestic construction 
material is no longer available, or (3) where the price has escalated so 
dramatically after the contract has been awarded that it would be 
unconscionable to require performance at that price. The determinations 
require by (1), (2) or (3) of this paragraph shall be at the sole 
discretion of the Secretary of Veterans Affairs.
    (e) By signing this bid, the bidder declares that all articles, 
materials and supplies for use on the project shall be domestic unless 
specifically set forth on the Bid Form or addendum thereto.

                             (End of clause)

[50 FR 798, Jan. 7, 1985, as amended at 54 FR 40066, Sept. 29, 1989]



852.236-90  Restriction on submission and use of equal products.

    As prescribed in 836.202(c), the following clause shall be included 
in the solicitation if it is determined that only one product will meet 
the Government's minimum needs and the Department of Veterans Affairs 
will not allow the submission of ``equal'' products:

     Restriction on Submission and Use of Equal Products (Nov 1986)

    This clause applies to the following items:

 _______________________________________________________________________

________________________________________________________________________

________________________________________________________________________

    Notwithstanding the ``Material and Workmanship'' clause of this 
contract, FAR 52.236-5(a), nor any other contractual provision, 
``equal'' products will not be considered by the Department of Veterans 
Affairs and may not be used.

                             (End of clause)

[52 FR 282, Jan. 5, 1987, as amended at 53 FR 7756, Mar. 10, 1988]



852.236-91  Special notes.

                        Special Notes (Jan. 1988)

    (a) Signing of the bid shall be deemed to be a certification by the 
bidder that:
    (1) Bidder is a construction contractor who owns, operates, or 
maintains a place of business, regularly engaged in construction, 
alteration or repair of buildings, structures,

[[Page 247]]

communication facilities, or other engineering projects, including 
furnishing and installing of necessary equipment; or
    (2) If newly entering into a construction activity, bidder has made 
all necessary arrangements for personnel, construction equipment, and 
required licenses to perform construction work; and
    (3) Upon request, prior to award, bidder will promptly furnish to 
the Government a statement of facts in detail as to bidder's previous 
experience (including recent and current contracts), organization 
(including company officers), technical qualifications, financial 
resources and facilities available to perform the contemplated work.
    (b) Unless otherwise provided in this contract, where the use of 
optional materials or construction is permitted the same standard of 
workmanship, fabrication and installation shall be required irrespective 
of which option is selected. The contractor shall make any change or 
adjustment in connecting work or otherwise necessitated by the use of 
such optional material or construction, without additional cost to the 
Government.
    (c) When approval is given for a system component having functional 
or physical characteristics different from those indicated or specified, 
it is the responsibility of the contractor to furnish and install 
related components with characteristics and capacities compatible with 
the approved substitute component as required for systems to function as 
noted on drawings and specifications. There shall be no additional cost 
to the Government.
    (d) In some instances it may have been impracticable to detail all 
items in specifications or on drawings because of variances in 
manufacturers' methods of achieving specified results. In such instances 
the contractor will be required to furnish all labor, materials, 
drawings, services and connections necessary to produce systems or 
equipment which are completely installed, functional, and ready for 
operation by facility personnel in accordance with their use.
    (e) Claims by the contractor for delay attributed to unusually 
severe weather must be supported by climatological data covering the 
period and the same period for the 10 preceding years. When the weather 
in question exceeds in intensity or frequency the 10 year average, the 
excess experienced shall be considered ``unusually severe.'' Comparison 
shall be on a monthly basis. Whether or not unusually severe weather in 
fact delays the work will depend upon the effect of weather on the 
branches of work being performed during the time under consideration.

                             (End of clause)

[53 FR 1632, Jan. 21, 1988, as amended at 61 FR 11587, Mar. 21, 1996]



852.237-7   Indemnification and Medical Liability Insurance.

    As prescribed in 837.403, insert the following clause:

     Indemnification and Medical Liability Insurance (October 1996)

    (a) It is expressly agreed and understood that this is a nonpersonal 
services contract, as defined in Federal Acquisition Regulation (FAR) 
37.101, under which the professional services rendered by the Contractor 
or its health-care providers are rendered in its capacity as an 
independent contractor. The Government may evaluate the quality of 
professional and administrative services provided but retains no control 
over professional aspects of the services rendered, including by 
example, the Contractor's or its health-care providers' professional 
medical judgment, diagnosis, or specific medical treatments. The 
Contractor and its health-care providers shall be liable for their 
liability-producing acts or omissions. The Contractor shall maintain or 
require all health-care providers performing under this contract to 
maintain, during the term of this contract, professional liability 
insurance issued by a responsible insurance carrier of not less than the 
following amount(s) per specialty per occurrence: [Contracting Officer 
insert the dollar value(s) of standard coverage(s) prevailing within the 
local community as to the specific medical specialty, or specialties, 
concerned, or such higher amount as the Contracting Officer deems 
necessary to protect the Government's interests]. However, if the 
Contractor is an entity or a subdivision of a State that either provides 
for self-insurance or limits the liability or the amount of insurance 
purchased by State entities, then the insurance requirement of this 
contract shall be fulfilled by incorporating the provisions of the 
applicable State law.
    (b) An apparently successful offeror, upon request of the 
Contracting Officer, shall, prior to contract award, furnish evidence of 
the insurability of the offeror and/or of all health-care providers who 
will perform under this contract. The submission shall provide evidence 
of insurability concerning the medical liability insurance required by 
paragraph (a) of this clause or the provisions of State law as to self-
insurance, or limitations on liability or insurance.
    (c) The Contractor shall, prior to commencement of services under 
the contract, provide to the Contracting Officer Certificates of 
Insurance or insurance policies evidencing the required insurance 
coverage and an endorsement stating that any cancellation or material 
change adversely affecting the Government's interest shall not be 
effective until 30 days after the insurer or the

[[Page 248]]

Contractor gives written notice to the Contracting Officer. Certificates 
or policies shall be provided for the Contractor and/or each health-care 
provider who will perform under this contract.
    (d) The Contractor shall notify the Contracting Officer if it, or 
any of the health- care providers performing under this contract, change 
insurance providers during the performance period of this contract. The 
notification shall provide evidence that the Contractor and/or health-
care providers will meet all the requirements of this clause, including 
those concerning liability insurance and endorsements. These 
requirements may be met either under the new policy, or a combination of 
old and new policies, if applicable.
    (e) The Contractor shall insert the substance of this clause, 
including this paragraph (e), in all subcontracts for health-care 
services under this contract. The Contractor shall be responsible for 
compliance by any subcontractor or lower-tier subcontractor with the 
provisions set forth in paragraph (a) of this clause.

    (End of Clause)
[61 FR 52710, Oct. 8, 1996]



852.237-70  Contractor responsibilities.

    (a) Fixed-Price negotiated or advertised service contracts, other 
than automobile, ambulance and aircraft services, will include the 
following clause:

                 Contractor Responsibilities (Apr 1984)

    The contractor shall obtain all necessary licenses and/or permits 
required to perform this work. He/she shall take all reasonable 
precautions necessary to protect persons and property from injury or 
damage during the performance of this contract. He/she shall be 
responsible for any injury to himself/herself, his/her employees, as 
well as for any damage to personal or public property that occurs during 
the performance of this contract that is caused by his/her employee's 
fault or negligence, and shall maintain personal liability and property 
damage insurance having coverage for a limit as required by the laws of 
the State of ______. Further, it is agreed that any negligence of the 
Government, its officers, agents, servants and employees, shall not be 
the responsibility of the contractor hereunder with the regard to any 
claims, loss, damage, injury and liability resulting therefrom.

                             (End of clause)

    (b) Automobile, ambulance and aircraft service contracts will 
utilize the clause prescribed in 852.237-71.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.237-71  Indemnification and insurance (vehicle and aircraft service contracts).

    (a) Contracts for vehicle and aircraft services will utilize the 
following clause as provided in 828.306.

                Indemnification and Insurance (Apr 1984)

    (a) Indemnification. The contractor expressly agrees to indemnify 
and save the Government, its officers, agents, servants, and employees 
harmless from and against any and all claims, loss, damage, injury, and 
liability, however caused, resulting from, arising out of, or in any way 
connected with the performance of work under this agreement. Further, it 
is agreed that any negligence or alleged negligence of the Government, 
its offficers, agents, servants, and employees, shall not be a bar to a 
claim for indemnification unless the act or omission of the Government, 
its officers, agents, servants, and employees is the sole, competent, 
and producing cause of such claims, loss, damage, injury, and liability. 
At the option of the contractor, and subject to the approval by the 
contracting officer of the sources, insurance coverage may be employed 
as guaranty of indemnification.
    (b) Insurance. Satisfactory insurance coverage is a condition 
precedent to award of a contract. In general, a successful bidder must 
present safisfactory evidence of full compliance with State and local 
requirements, or those below stipulated, whichever are the greater. More 
specifically, workman's compensation and employer's liability coverage 
will conform to applicable State law requirements for the service 
contemplated, whereas general liability and automobile liability of 
comprehensive type, shall in the absence of higher statutory minimums, 
be required in the amounts per vehicle used of not less than $200,000 
per person and $500,000 per occurrence for bodily injury and $20,000 per 
occurrence for property damage. State approved sources of insurance 
coverage ordinarily will be deemed acceptable to the Veterans' 
Administration installation, subject to timely certifications by such 
sources of the types and limits of the

[[Page 249]]

coverages afforded by the sources to the bidder. (In those instances 
where airplane service is to be used, substitute the word ``aircraft'' 
for ``automobile'' and ``vehicle'' and modify coverage to require 
aircraft public and passenger liability insurance of at least $200,000 
per passenger and $500,000 per occurrence for bodily injury, other than 
passenger liability, and $200,000 per occurrence for property damage. 
Coverage for passenger liability bodily injury shall be at least 
$200,000 multiplied by the number of seats or passengers, whichever is 
greater.)

                             (End of clause)

    (b) Exceptions. The provisions of this 852.237-71 do not apply to 
emergency or sporadic ambulance service authorized by VA Manual MP-1, 
Part II, Chapter 3: Provided, That such service is not used solely for 
the purpose of avoiding entering into a continuing contract. Provided 
further, That such services will be obtained from firms known to carry 
insurance coverage in accordance with State or local requirements.
[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.247-70  Transportation provision for bid evaluation.

    In circumstance enunciated in 847.305-70, the following provision 
will be inserted in the IFB:

     Determining Transportation Costs for Bid Evaluation (Apr 1984)

    For the purpose of evaluating bids and for not other purpose, the 
delivered price per unit will be determined by adding the nationwide 
average transportation charge to the f.o.b. origin bid prices. The 
nationwide average transportation charge will be determined by applying 
the following formula: Multiply the guaranteed shipping weight by the 
freight, parcel post, or express rate, whichever is proper, to each 
destination shown below and then multiply the resulting transportation 
charges by the anticipated demand factor shown for each destination. 
Total the resulting weighted transportation charges for all destinations 
and divide the total by 20 to give the nationwide average transportation 
charge.

                           Anticipated Demand                           
                                                                        
                                                                        
                                                                        
Area destination:                                                 Factor
  Oakland, California.........................................         3
  Dallas, Texas...............................................         2
  Omaha, Nebraska.............................................         3
  Fort Wayne, Indiana.........................................         4
  Atlanta, Georgia............................................         3
  New York, New York..........................................         5
                                                               ---------
    Total of factors..........................................        20
                                                                        

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 798, Jan. 7, 1985]



852.270-1  Representatives of contracting officers.

    Whenever it is considered necessary to designate a representative 
under 801.603-70, the following provision will be made a part of the 
request for proposal or invitation to bid:

           Representatives of Contracting Officers (Apr 1984)

    The contracting officer reserves the right to designate 
representatives to act for him/her in furnishing technical guidance and 
advice or generally supervise the work to be performed under this 
contract. Such designation will be in writing and will define the scope 
and limitations of the designee's authority. A copy of the designation 
shall be furnished the contractor.

                           (End of Provision)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 798, Jan. 7, 1985]



852.270-2  Bread and bakery products.

    The following clause will be inserted in all contracts for bread and 
bakery products:

                          Quantities (Apr 1984)

    The bidder agrees to furnish up to 25 percent more or 25 percent 
less than the quantities awarded when ordered by the Department of 
Veterans Affairs.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



 852.270-3  Purchase of shell fish.

    Invitations for bids or requests for proposals covering oysters, 
clams or mussels, fresh or frozen, will contain the following clause:

                          Shellfish (Apr 1984)

    The bidder certifies that oysters, clams, and mussels will be 
furnished only from plants approved by and operated under the 
supervision of shell fish authorities of States whose certifications are 
endorsed currently

[[Page 250]]

by the U.S. Public Health Service, and the names and certificate numbers 
of those shell fish dealers must appear on current lists published by 
the U.S. Public Health Service. These items shall be packed and 
delivered in approved containers, sealed in such manner that tampering 
is easily discernible, and marked with packer's certificate number 
impressed or embossed on the side of such containers and preceded by the 
State abbreviation. Containers shall be tagged or labeled to show the 
name and address of the approved producer or shipper, the name of the 
State of origin, and the certificate number of the approved producer or 
shipper.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 798, Jan. 7, 1985]



 852.270-4  Commercial advertising.

    All VA contracts will include the following clause:

                    Commercial Advertising (Nov 1984)

    The bidder or offeror agrees that if a contract is awarded to him/
her, as a result of this solicitation, he/she will not advertise the 
award of the contract in his/her commercial advertising in such a manner 
as to state or imply that the Department of Veterans Affairs endorses a 
product, project or commercial line of endeavor.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, 798, Jan. 7, 1985]



 852.271-70  Services provided eligible beneficiaries.

    The following clause will be included in all contracts covering 
services provided to eligible beneficiaries:

     Nondiscrimination in Services Provided Beneficiaries (Apr 1984)

    The contractor agrees to provide all services specified in this 
contract for any person determined eligible by the Chief Medical 
Director, or designee, regardless of the race, color, religion, sex, or 
national origin of the person for whom such services are ordered. The 
contractor further warrants that he/she will not resort to 
subcontracting as a means of circumventing this provision.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



 852.271-71  Visits to Department of Veterans Affairs guidance centers.

    The following clause will be included in contracts entered into for 
services relating to vocational counseling:

                          Inspection (Apr 1984)

    Any duly authorized representative of the Department of Veterans 
Affairs shall at all reasonable times be permitted to inspect the 
counseling and testing operations being performed under this contract 
and the records of these operations.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



 852.271-72  Time spent by counselee in counseling process.

    Insert the following clause in contracts entered into for services 
relating to vocational counseling:

        Time Spent by Counselee in Counseling Process (Apr 1984)

    The contractor agrees that no counselee referred under the 
provisions of this agreement will be required to give any extra time in 
connection with the counseling process to supply test results or other 
information for purposes other than those specified in this contract.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.271-73  Use and publication of counseling results.

    Insert the following clause in contracts entered into for services 
relating to vocational counseling:

                      Publishing Results (Apr 1984)

    The contractor agrees that none of the information or data gathered 
in connection with the services specified in this contract or studies or 
materials based thereon or relating thereto will be publicized without 
the prior approval of the Chief Benefits Director or his/her designee.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.271-74  Inspection.

    Insert the following clause in contracts entered into with 
educational

[[Page 251]]

institutions and training establishments for education and 
rehabilitation:

                          Inspection (Apr 1984)

    The contractor will permit the duly authorized representative of the 
Department of Veterans Affairs to visit the place of instruction as may 
be necessary and examine the training facilities and work of the 
veterans in training under this contract.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



852.271-75  Extension of contract period.

    The following clause will be included in contracts where appropriate 
pertaining to services for education and rehabilitation:

                 Extension of Contract Period (Apr 1984)

    This contract may be extended from year to year if agreeable to both 
parties provided the agreement for extension is consummated 30 days 
prior to the expiration date, and further provided that there is no 
change in the provisions, terms, conditions, or rate of payment. Any 
extension made hereunder is subject to the availability of funds during 
the period covered by the extension.

                             (End of clause)

[49 FR 12629, Mar. 29, 1984, as amended at 50 FR 794, Jan. 7, 1985]



PART 853--FORMS--Table of Contents




Sec.
853.000  Scope of part.

                         Subpart 853.1--General

853.107  Obtaining forms.

                  Subpart 853.2--Prescription of Forms

853.201  Federal acquisition system.
853.201-1  Contracting authority and responsibilities (SF 1402).
853.213  Small purchase and other simplified purchase procedures (VA 
          Forms 90-2138, 10-7078, 10-7079, 10-2570d, 10-2511, and 10-
          2421).
853.215  Contracting by negotiation (VA Form 10-1170).
853.236  Construction and architect-engineer contracts.
853.236-1  [Reserved]
853.236-2  Architect-engineer services (VA Form 08-6298).
853.271  Loan Guaranty, Education and Vocational Rehabilitation and 
          Counseling Programs.
853.271-1  Loan Guaranty Program (VA Forms 26-6724 and 26-1839).
853.271-2  Vocational Rehabilitation and Counseling Programs (VA Forms 
          22-1903, 22-1905 and 22-1931).
853.271-3  Education Programs (VA Forms 22-1982, 22-1982e, 22-1982c, and 
          22-7398).

                  Subpart 853.3--Illustration of Forms

853.300  Scope of subpart.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12639, Mar. 29, 1984, unless otherwise noted.



853.000  Scope of part.

    This part prescribes Department of Veterans Affairs forms for use in 
the acquisition of goods and services. It only identifies forms which 
are used between VA and its contractors or the general public. It does 
not identify forms for uses internal to VA or between VA and another 
Federal agency.
[49 FR 12639, Mar. 29, 1984, as amended at 54 FR 40066, Sept. 29, 1989]



                         Subpart 853.1--General



853.107  Obtaining forms.

    VA forms may be obtained from any VA contracting office or by 
requesting such forms from the Deputy Assistant Secretary for 
Acquisition and Materiel Management (91), Department of Veterans 
Affairs, 810 Vermont Avenue NW., Washington, DC 20420.
[49 FR 12639, Mar. 29, 1984; 50 FR 798, Jan. 7, 1985; 54 FR 40066, Sept. 
29, 1989]



                  Subpart 853.2--Prescription of Forms



853.201  Federal acquisition system.



853.201-1  Contracting authority and responsibilities (SF 1402).

    Current delegations of contracting authority appointed with VA Form 
90-2267, Certificate of Designation (contracting officer), will remain 
in effect until replaced with an executed SF 1402, Certificate of 
Appointment, in accordance with 801.603-3.

[[Page 252]]



853.213  Small purchase and other simplified purchase procedures (VA Forms 90-2138, 10-7078, 10-7079, 10-2570d, 10-2511, and 10-2421).

    The following forms are prescribed as stated below and in the 
circumstances and within the limitations provided:
    (a) VA Form 90-2138, Order for Supplies or Services shall be used as 
indicated in 813.505-2. It will be used in lieu of but similar to OF 
347, Order for Supplies and Services.
    (b) The following forms are for use for obtaining indicated medical 
and dental services within the limitations prescribed in 813.505-2:
    (1) VA Form 10-7078, Authorization and Invoice for Medical and 
Hospital Services.
    (2) VA Form 10-7079, Request for Outpatient Medical Services.
    (3) VA Form 10-2570d, Dental Record, Authorization and Invoice for 
Outpatient Services.
    (c) VA Form 10-2511, Authority and Invoice for Travel by Ambulance 
or Other Hired Vehicle, will be used as prescribed in 813.505-2(c).
    (d) VA Form 10-2421. Prosthetics Authorization and Invoice, will be 
used from indicated procurements not to exceed $300 as prescribed in 
813.505-2.
[49 FR 12639, Mar. 29, 1984, as amended at 50 FR 798, Jan. 7, 1985]



853.215  Contracting by negotiation (VA Form 10-1170).

    VA Form 10-1170, Application for Furnishing Nursing Home Care to 
Beneficiaries of the Department of Veterans Affairs, will be utilized 
for establishing contract nursing home care for VA beneficiaries.



853.236  Construction and architect-engineer contracts.



853.236-1  [Reserved]



853.236-2  Architect-engineer services (VA Form 08-6298).

    VA Form 08-6298, Architect-Engineer Fee Proposal, will be used as 
prescribed in 836.606-71.



853.271  Loan Guaranty, Education, and Vocational Rehabilitation and Counseling Programs.



853.271-1  Loan Guaranty Program (VA Forms 26-6724 and 26-1839).

    (a) VA Form 26-6724, Invitation, Bid, and/or Acceptance or 
Authorization, will be used in obtaining services specified in subpart 
871.1.
    (b) VA Form 26-1839, Compliance Inspection Report, will be used for 
inspection of repairs for properties under the Loan Guaranty Program as 
specified in 846.472.



853.271-2  Vocational Rehabilitation and Counseling Programs (VA Forms 22-1903, 22-1905, and 22-1931).

    The following forms will be used in acquiring education or 
rehabilitation services as prescribed in subpart 871.2:
    (a) VA Form 22-1903, Contract for Education and Training.
    (b) VA Form 22-1905, Authorization and Certification of Entrance or 
Reentrance into Training and Certification of Trainee Status.
    (c) VA Form 22-1931, Contract for Services Relating to Vocational 
Counseling.



853.271-3  Education Programs (VA Forms 22-1982, 22-1982e, 22-1982c, and 22-7398).

    The following forms are prescribed for use in obtaining services for 
the Veterans Benefits Administration Education programs:
    (a) VA Form 22-1982, State Approving Agency (SAA) Reimbursement 
Contract.
    (b) VA Form 22-1982e, Schedule No. 1 to the SAA Reimbursement 
Contract; Accredited and Non-Accredited Courses Under Chapter 32, 34, 
and 35, or 36, of Title 38 United States Code, whichever is applicable.
    (c) VA Form 1982c, Schedule No. 2 to the SAA Reimbursement Contract; 
Apprentice Or Other Training On-the-Job.
    (d) VA Form 22-7398, Quarterly Report of State Approving Agency 
Activities Under Chapter 36, Title 38, United States Code.

[[Page 253]]



                  Subpart 853.3--Illustration of Forms



853.300  Scope of subpart.

    VA Forms will not be illustrated in this VAAR. Persons wishing to 
obtain copies of VA forms prescribed in the VAAR may do so in accordance 
with 853.107.

[[Page 254]]



           SUBCHAPTER I--DEPARTMENT SUPPLEMENTARY REGULATIONS





PART 870--SPECIAL PROCUREMENT CONTROLS--Table of Contents






                         Subpart 870.1--Controls

Sec.
870.111  Subsistence.
870.111-5  Frozen processed food products.
870.112  Telecommunications equipment.
870.113  Paid use of conference facilities.
870.114  Asbestos.
870.114-1  General.
870.114-2  Background.
870.114-3  Approving authority.
870.114-4  Exempted products containing asbestos.
870.115  Food service equipment.

    Authority:  38 U.S.C. 210 and 40 U.S.C. 486(c).

    Source:  49 FR 12640, Mar. 29, 1984, unless otherwise noted.



                         Subpart 870.1--Controls



870.111  Subsistence.



870.111-5  Frozen processed food products.

    (a) All frozen, processed food products procured which contain meat, 
poultry or a significant proportion of eggs, will be processed or 
prepared in plants operated under the supervision of the U.S. Department 
of Agriculture (USDA). The product will be inspected and approved in 
accordance with the regulations of the USDA governing meat, poultry or 
egg inspection. A label or seal, affixed to the container, indicating 
compliance with these regulations will be accepted as evidence of 
compliance. The product must bear a label complying with the Federal 
Food, Drug and Cosmetic Act which requires that all ingredients be 
listed according to the order of their predominance.
    (b) All frozen, processed food products procured which contain fish 
or fish products will be processed or prepared in plants operated under 
the supervision of the U.S. Department of Commerce (USDC). The products 
listed in USDC publication titled, ``Approved List of Sanitarily 
Inspected Fish Establishments'' are processed in plants under Federal 
inspection of the National Marine Fisheries Service, National Oceanic 
and Atmospheric Administration, U.S. Department of Commerce. The 
inspected products packed under various labels bearing the brand names 
are produced in accordance with current U.S. Grade Standards or official 
product specifications, packed under optimum hygienic conditions, and 
must meet Federal, State, and city sanitation and health regulations. 
Such brand label or USDC seal, affixed to a container, indicating 
compliance with USDC regulations will be accepted as evidence of 
compliance. In lieu thereof, the shipment may be lot inspected by the 
USDC and containers stamped to indicate acceptance or a Certification of 
Inspection issued to accompany the shipment. The product must bear a 
label complying with the Federal Food, Drug and Cosmetic Act which 
requires that all ingredients be listed according to the order of their 
predominance.
    (c) Producers of frozen bakery products which are shipped in 
interstate commerce are required to comply with the Federal Food, Drug 
and Cosmetic Act. Therefore, it must be vertified that the product, in 
fact was shipped interstate or that the producer ships products to other 
purchasers interstate. In addition, the product must bear a label 
complying with the Act which requires that all ingredients be listed 
according to the order of their predominance.
[49 FR 12640, Mar. 29, 1984, as amended at 54 FR 40066, Sept. 29, 1989]



870.112  Telecommunications equipment.

    (a) Solicitations, including those for construction, based on 
detailed purchase descriptions or formal specifications for 
telecommunications equipment, as defined in VA Manual MP-6, Part 
VIII,1 will include the clause required by 852.210-74.
---------------------------------------------------------------------------

    \1\ Available at any Veterans Administration facility.

---------------------------------------------------------------------------

[[Page 255]]

    (b) The descriptive literature to be furnished by the contractor 
after award, required by the clause in 852.210-74, is to be reviewed and 
approved by the Office of Information Resources Operations prior to 
delivery and/or installation by the contractor. Promptly upon receipt of 
the descriptive literature, contracting officers will forward it 
together with a copy of the contract, the formal specification, or the 
detailed purchase description to the Deputy Assistant Secretary for 
Acquisition and Materiel Management (93).
    (c) Solicitations, including those for construction, for 
telecommunications equipment based on ``brand name or equal'' purchase 
description are subject to the following:
    (1) Prior to award, contracting officers will forward to the Deputy 
Assistant Secretary for Acquisition and Materiel Management (93), the 
abstract of bids, one copy of each offer received, including descriptive 
literature and pertinent letters, and the comments and recommendations 
of the contracting officer.
    (2) No commitments are to be made to contractors prior to receipt of 
Central Office reaction.
    (3) Allowance of at least 30 calendar days for acceptance will be 
specified in the solicitation in order to allow sufficient time for the 
review required by this paragraph (c). (See FAR 52.214-16.)
[49 FR 12640, Mar. 29, 1984, as amended at 50 FR 798, Jan. 7, 1985; 54 
FR 30044 and 30045, July 18, 1989; 54 FR 40066, Sept. 29, 1989]



870.113  Paid use of conference facilities.

    (a) The rental of space for VA-sponsored symposia and training 
sessions may be unwarranted when other alternatives are available at no 
expense or reduced expense to the Government. After the geographical 
location for a VA conference has been selected, based on minimum overall 
travel costs for all Government participants and other relevant factors, 
a request for conference space will be forwarded to the servicing Supply 
activity. The request for conference space should afford the contracting 
officer every opportunity to secure rent-free facilities.
    (b) The following criteria for the selection of an appropriate 
facility will apply:
    (1) A thorough effort will be made to schedule conferences and 
training sessions so that the conference facilities of VA installations 
in the city where the conference is held may be used.
    (2) Where no VA space is available, the General Services 
Administration will be contacted to determine if there is other 
Government agency space which may be used.
    (3) Efforts will be made to schedule conferences, where Government 
space is not available, through hotels and motels which offer free 
conference facilities in exchange for a stipulated number of lodging 
reservations for participants. Surcharges per lodging or increased room 
rates, to offset the cost of the conference room, shall be considered 
payment for such space.
    (4) In the event none of these is available on the desired dates, 
consideration will be given to rescheduling the conference to avail VA 
of the use of facilities without payment of a fee.
    (5) If none of the above is practical, rental conference space will 
be obtained. Complete documentation of efforts to secure free conference 
space, as outlined above, will be maintained in the purchase order file. 
The costs of coffee, refreshments, meals, lodging, tips and other 
supplies and services not directly related to the presentations within 
the conference space are not allowable.
    (c) The conference coordinator of the requesting organization will 
continue to be responsible for individual room reservations, including 
any cancellations.
[49 FR 12640, Mar. 29, 1984, as amended at 54 FR 40066, Sept. 29, 1989]



870.114  Asbestos.



870.114-1  General.

    This section applies to the purchase and use of asbestos products 
and equipment or materials containing asbestos products in the 
Department of Veterans Affairs.

[[Page 256]]



870.114-2  Background.

    Exposure to asbestos is associated with chronic and debilitating 
lung disease and cancer. To reduce the health hazard related to the 
exposure to asbestos, the U.S. Environmental Protection Agency and the 
U.S. Department of Labor (Occupational Safety and Health Administration) 
have issued specific regulations on asbestos. Although these regulations 
do not call for a complete ban on the use of asbestos, they do impose 
strict requirements on its use, airborne contamination and disposal.



870.114-3  Approving authority.

    Asbestos products and equipment or materials containing asbestos 
products shall not be specified nor purchased for use in the Department 
of Veterans Affairs if any suitable substitutes are available. If 
suitable substitutes are not available, specific authorization to 
purchase and use asbestos products and equipment or materials specifying 
asbestos products, must be granted by the Secretary or designee. 
Requests for authorization will be submitted through the Director, 
Facilities Engineering Service (085E). The following information will be 
provided:
    (a) The name of the product, source of supply, and physical form of 
asbestos as used in the product or equipment;
    (b) A description of use, including purpose, urgency, methodology, 
qualities, and by whom; and
    (c) Safeguards being employed, with particular emphasis on the 
identification of the asbestos products, and procedures to be taken to 
prevent airborne contamination and disposal.
[49 FR 12640, Mar. 29, 1984, as amended at 54 FR 40066, Sept. 29, 1989]



870.114-4  Exempted products containing asbestos.

    VA Central Office, Facilities Engineering Service (085E), is 
responsible for maintaining a list of products containing asbestos which 
are exempted by the Secretary or designee from this policy.
[49 FR 12640, Mar. 29, 1984, as amended at 54 FR 40066, Sept. 29, 1989]



870.115  Food service equipment.

    (a) All new food service equipment purchased for Dietetic Service 
through other than the Defense General Supply Center (DGSC) sources must 
meet requirements set forth by the National Sanitation Foundation (NSF).
    (b) The contracting officer will accept an affixed NSF label and/or 
documentation of the certification by NSF from the contractor as 
evidence that the subject equipment meets sanitation standards issued by 
the Foundation.



PART 871--LOAN GUARANTY AND VOCATIONAL REHABILITATION AND COUNSELING PROGRAMS--Table of Contents




                  Subpart 871.1--Loan Guaranty Program

Sec.
871.100  Scope of subpart.
871.101  Policy.
871.102  Authorization for repairs to properties.
871.104  Qualification of bidders.
871.106  Lien waivers.
871.107  Stipulations against liens.

     Subpart 871.2--Vocational Rehabilitation and Counseling Program

871.200  Scope of subpart.
871.201  General.
871.201-1  Requirements for the use of contracts.
871.201-2  Requirements when contracts are not required.
871.201-3  Medical services.
871.201-4  Letter contracts.
871.202  Marking and release of supplies.
871.203  Renewals or supplements to contracts.
871.204  Guaranteed payment.
871.205  Proration of charges.
871.206  Other fees and charges.
871.207  Payment of tuition or fees.
871.208  Rehabilitation facilities.
871.209  Records and reports.
871.210  Correspondence courses.
871.211  Information concerning correspondence courses.

               Subpart 871.3--Education Program [Reserved]

    Authority:  10 U.S.C. ch. 106, 107, 1606; 38 U.S.C. 501, ch. 30, 31, 
32, 35, 36, 37; 40 U.S.C. 486(c).

    Source:  49 FR 12641, Mar. 29, 1984, unless otherwise noted.

[[Page 257]]



                  Subpart 871.1--Loan Guaranty Program



871.100  Scope of subpart.

    This subpart sets forth policy and procedure with respect to the 
loan guaranty and direct loan programs as it pertains to property 
management, including the acquisition, management, and disposition of 
property, real, personal, or mixed, which were secured by loans 
guaranteed, insured, or made pursuant to Title 38, United States Code.



871.101  Policy.

    All acquisitions for the repair and maintenance of VA property 
acquired under 38 U.S.C. Chapter 37 shall be made in accordance with FAR 
Parts 14, 15, and 16; (VAAR) 48 CFR Parts 814, 815, and 816; and (VAAR) 
48 CFR subpart 871.1.

    (Authority: 10 U.S.C. ch. 106, 107, 1606; 38 U.S.C. 501, ch. 37; 40 
U.S.C. 486(c))
[61 FR 20493, May 7, 1996]



871.102  Authorization for repairs to properties.

    (a) Except as provided in this subpart, Directors, Loan Guaranty 
Officers, and Assistant Loan Guaranty Officers VA Regional Offices, are 
authorized to approve a repair program for any Department of Veterans 
Affairs property acquired under Chapter 37, Title 38, United States 
Code, where the cost does not exceed $25,000. A repair program means the 
aggregate amount of the proposed contracts which are contemplated in a 
property analysis by the Loan Guaranty activity.
    (b) In those cases where the expenditure is known or estimated to 
exceed $25,000, the request, together with the loan guaranty folder, 
will be forwarded to the Under Secretary for Benefits for approval.
    (c) During the period when the Department of Veterans Affairs has 
assumed custody of the property from a holder and prior to its 
conveyance to the Deparment of Veterans Affairs pursuant to 38 CFR 
36.4320, repairs are authorized not in excess of $3,500 when appropriate 
to make the property ready for sale at an earler date than would 
otherwise be possible if the repair program was delayed until such time 
as the Department of Veterans Affairs acquired absolute title. In those 
cases where the expenditure is known or estimated to exceed $3,500, the 
request, together with the loan guarantee folder, will be forwarded to 
the Under Secretary for Benefits for approval.
    (d) No repairs may be made to property by the holder when it has 
continued custody except for emergeny repairs not in excess of $500 
unless adequate notice has been given the Director, VA Regional Office. 
Emergency repairs as applied in this paragraph will be deemed to mean 
those requiring immediate action to preserve the property from serious 
damage or to correct a situation imminently dangerous to life or limb, 
and includes the initial cleanup of the property in order to prevent the 
risk of damage by fire or vandalism.
    (e) An approved management broker may be authorized, at the time a 
property is assigned, to incur expenses for fuel and utilities or other 
recurring items which are required to be furnished by the Department of 
Veterans Affairs to its tenants or are required in the maintenance of 
the property. Advance blanket authorizations to management brokers will 
be limited to repairs not in excess of $500 in any transaction, (the 
management broker will either submit receipts with the invoice or 
maintain such receipts for inspection). Expenditures in excess of $500 
require prior approval of the Director, Regional Office, having 
jurisdiction of the property. Repair jobs may not be split to circumvent 
this restriction.
[49 FR 12641, Mar. 29, 1984, as amended at 55 FR 31600, Aug. 3, 1990; 61 
FR 20493, 20494, May 7, 1996]



871.104  Qualification of bidders.

    (a) Qualification of bidders shall be established in accordance with 
procedures outlined in FAR Subpart 9.1 and subpart 809.1 of this 
chapter.
    (b) Management brokers are not considered acceptable bidders for 
repair contracts due to their close association on a fee basis with the 
Department of Veterans Affairs. This restriction would apply equally to 
any contracting firm in which the management broker

[[Page 258]]

has an interest and in which it could be presumed that such firm would 
have an advantage over the other bidders. This does not preclude the 
performance of work by management brokers of a routine recurring 
maintenance category or minor repairs by personnel employed directly on 
the payroll of the broker. In these cases, it must be established that 
any charges for such services are not in excess of the prevailing fees 
for like services in the area.



871.106  Lien waivers.

    (a) Contracts in the amount of $2,500 or more will contain a 
requirement that the contractor will sign a formal release in full or a 
lien waiver before payment may be made. The release or waiver will 
accompany the contractor's invoice.
    (b) Contractors will be required to notify the Director, Regional 
Office, of any subcontractors for services or materials in excess of 
$2,500. Such subcontractors will be required to sign the release or 
waiver jointly with the prime contractor or to execute release or waiver 
in the subcontractor's own name.
    (c) Prior to any authorized partial payment the contractor will be 
required to execute a release or waiver.
    (d) Due to the variations of local law, no standard release or 
waiver is prescribed. Each release or waiver will be prepared in 
accordance with local law and will be in form acceptable by the District 
Counsel.
[49FR 12641, Mar. 29, 1984, as amended at 61 FR 20494, May 7, 1996]



871.107  Stipulations against liens.

    (a) Where determined necessary by the Director, Regional Office, 
contracts in an amount less than $2,500 may contain the following:

    The contractor expressly waives any and all rights to file or 
maintain any mechanics lien or claim against the aforesaid premises.

    (b) Contracts in the amount of $2,500 or more where there is doubt 
as to the final responsibility of the contractor will provide maximum 
potection to the Government by including such requirements as are 
available under local law. Advice and approval of any contract 
stipulation or legal stipulations against liens will be obtained from 
the District Counsel.



     Subpart 871.2--Vocational Rehabilitation and Counseling Program



871.200  Scope of subpart.

    This subpart establishes policy and procedures for the vocational 
rehabilitation and counseling program as it pertains to contracts for 
training and rehabilitation services, approval of institutions 
(including rehabilitation facilities), training establishments, and 
employers under 38 U.S.C. Chapter 31, and contracts for counseling 
services under 38 U.S.C. Chapters 30, 31, 32, 35, and 36 and 10 U.S.C. 
Chapters 106, 107, and 1606.

    (Authority: 10 U.S.C. ch. 106, 107, 1606; 38 U.S.C. 501, ch. 30, 31, 
32, 35, 36; 40 U.S.C. 486(c))
[61 FR 20494, May 7, 1996]



871.201  General.



871.201-1  Requirements for the use of contracts.

    Contracts will be negotiated for tuition, fees, books, supplies and 
other allowable expenses incurred by the institution, training 
establishment or employer for the training and rehabilitation of 
eligible veterans under Chapter 31, Title 38, United States Code, under 
the following conditions:
    (a) With institutions offering courses of instruction by 
correspondence. Courses of instruction by correspondence is deemed to 
mean a course of education or training conducted by mail consisting of 
regular lessons or reading assignments, the preparation of required 
written work which involves the application of principles studied in 
each lesson, the correction of assigned work with such suggestions or 
recommendation as may be necessary to instruct the student, the keeping 
of student achievement records and issuance of a diploma, certificate, 
or other evidence to the student upon satisfactorily completing the 
requirements of the course.
    (b) With institutions, training establishments, employers, or 
individuals

[[Page 259]]

approved to provide training and rehabilitation services under Chapter 
31, Title 38, United States Code, for whom special services or special 
courses are furnished at the request of the Department of Veterans 
Affairs. The terms ``special services'' or ``special courses'' have the 
same meaning as under 831.7001-2.
[49 FR 12641, Mar. 29, 1984; 50 FR 798, Jan. 7, 1985]



871.201-2  Requirements when contracts are not required.

    (a) When a contract is not required, a signed statement of charges 
will be obtained from the educational institution or training 
establishment for courses to be offered, including the rate of tuition, 
fees, and separate charges, if any, for books, supplies, and equipment 
handling charges, refund policy and such other provisions as are 
required to determine proper payment. The statement of charges may be in 
the form of a statement on VA Form 22-1905, Authorization and 
Certification of Entrance or Reentrance into Training, that charges will 
be in accordance with catalog or other published document (identify 
publication). The statement of charges may not exceed those charges paid 
by nonveterans or that is published in the school catalog or other 
published document.
    (b) For the purpose of this section a contract will not be required 
when all tuition, fees, books, supplies, or services necessary to train, 
or educate an eligible veteran under Chapter 31, Title 38, United States 
Code, are published in the school catalog or other published document.
[49 FR 12641, Mar. 29, 1984; 50 FR 798, Jan. 7, 1985]



871.201-3  Medical services.

    The medical services provided trainees under vocational 
rehabilitation and education contracts, agreements, or arrangements are 
separate and distinct from any other medical service under the 
jurisdiction of the Veterans Health Administration to which the veteran 
may be entitled and no certificate of eligibility is required from that 
administration.
[49 FR 12641, Mar. 29, 1984, as amended at 54 FR 40066, Sept. 29, 1989; 
61 FR 20494, May 7, 1996]



871.201-4  Letter contracts.

    Letter contracts are authorized for use in accordance with the 
provision of FAR 16.603 and in those cases in which it is not possible 
to complete a formal contract with an approved educational institution 
prior to the enrollment of eligible veterans for training.



871.202  Marking and release of supplies.

    Supplies will not be marked to indicate ownership by the United 
States and will be deemed released to the trainee at the time they are 
furnished.



871.203  Renewals or supplements to contracts.

    Except for contracts for educational and vocational counseling, 
contracts may be renewed from year to year, providing there is no change 
in the schedule or provisions as originally consummated by completion of 
a renewal agreement no later than 30 days prior to the expiration of the 
contract.
    (a) Supplements may be negotiated at any time during the contract 
period upon the completion of the supplemental agreement.
    (b) Contracts for educational and vocational counseling may provide 
for automatic extension from year to year.



871.204  Guaranteed payment.

    No contract or agreement may be entered into with any institution or 
training establishment whereby the Department of Veterans Affairs will 
be required to pay a minimum charge, or required to enroll a minimum 
number of participants per quarter, semester, term, course, or other 
period.
[49 FR 12641, Mar. 29, 1984; 50 FR 798, Jan. 7, 1985]



871.205  Proration of charges.

    The contract will include the exact formula agreed on for the 
proration of charges in the event that the veteran's program is 
interrupted or discontinued prior to the end of the term, semester,

[[Page 260]]

quarter, or other period, or the program is completed in less time than 
stated in the contract.



871.206  Other fees and charges.

    Fees and other charges which are not prescribed by law but are by 
nongovernmental organizations, such as initiation fees required to 
become a member of a labor union and the dues necessary to maintain 
membership incidental to training on the job or to obtaining employment 
during a period in which the veteran is a Chapter 31 participant, may be 
paid provided there are no facilities feasibly available whereby the 
necessary training can be feasibly accomplished or employment obtained 
without paying such charges. Payment for such fees will be made in 
accordance with part 813.
[49 FR 12641, Mar. 29, 1984, as amended at 54 FR 40066, Sept. 29, 1989]



871.207  Payment of tuition or fees.

    (a) Contracts, agreements, or arrangements requiring the payment of 
tuition or fees will provide for the following:
    (1) Payment for tuition or fees will be made in arrears and will be 
prorated in installments over the school year or the length of the 
course except that institutions may be paid in accordance with the 
provision of paragraph (a)(2) of this section, provided such 
institutions operate on a regular term, quarter, or semester basis and 
normally accept students only at the beginning of the term, quarter, or 
semester and provided for further such institutions are either:
    (i) Institutions of higher learning that use a standard unit of 
credit recognized by accrediting associations (such institutions will 
include those which are members of recognized national or regional 
educational accrediting associations, and those which, although not 
members of such accrediting associations, grant standard units of credit 
acceptable at full value without examination by collegiate institutions 
which are members of national or regional accrediting associations).
    (ii) Public tax supported institutions.
    (iii) Institutions operated and controlled by State, county, or 
local boards of education.
    (2) Institutions coming within the exceptions of paragraph (a)(1) of 
this section which have a refund policy providing for a graduated scale 
of charges for purposes of determining refunds may be paid part or all 
such tuitions or fees for a term, quarter, or other period of enrollment 
immediately following the date on which the refund expires.
    (3) Proration of charges will not apply to a fee which is for 
noncontinuing service such as registration fee, etc.
    (b) The period for which payment of charges may be made will be the 
period of actual enrollment and subject to the following:
    (1) The effective date will be the date of the trainee's entrance 
into training status except that payment may be made for an entire-
semester, quarter, or term in institutions operating on that basis if 
the trainee enters no later than the final date set by the institution 
for enrolling for full credit.
    (2) In those cases where the institution has not set a final date 
for enrolling for full credit or will not set a date acceptable to the 
Department of Veterans Affairs, payment may be prorated on the basis of 
attendance regardless of the refund policy.
    (3) If an institution customarily charges for the amount of credit 
or number of hours of attendance for which a trainee enrolls, payment 
may be made on that basis when a trainee enrolls after the final date 
permitted for carrying full credit for the semester or term.
    (c) The terminal date to which payment will be made is the day 
following:
    (1) The end of the semester, term or quarter during which the 
training is furnished.
    (2) The date of interruption or discontinuance of training.
    (3) The date of completion of the course.
[49 FR 12641, Mar. 29, 1984, as amended at 50 FR 798, Jan. 7, 1985; 61 
FR 20494, May 7, 1996]



871.208  Rehabilitation facilities.

    The provisions for payment of charges to rehabilitation facilities 
for the rehabilitation services provided under Chapter 31 are paid in 
the same manner as charges for educational and

[[Page 261]]

vocational services through contract, agreement, or other arrangement.



871.209  Records and reports.

    Contracts, agreements, or arrangements will provide for the number 
and frequency of reports, adequate financial records to support payment 
for each trainee and maintenance of attendance and progress records. 
Such records will be preserved for a period of three years.



871.210  Correspondence courses.

    Contracts with institutions for correspondence courses will provide 
that:
    (a) Major changes in courses or course material will not be binding 
on the Department of Veterans Affairs until such time as a supplemental 
agreement is negotiated to the contract.
    (b) Minor changes in course or course material not affecting the 
length of the course or number of lessons and not lowering the 
educational value of the course or the quality of the course material 
such as revision of text, the substitution of a newer lesson for an 
older one, or the substitution of equipment of equal or greater value, 
are permitted without supplemental agreements. Such minor changes and 
revisions shall be placed on file with the contracting officer at the 
time of the change or revision.
    (c) Trainees be provided with prompt and adequate lesson service 
and, unless otherwise specified in the contract, be furnished the same 
texts, lessons service, diplomas, and other services as are normally 
provided for regularly enrolled nonveteran students.
    (d) All lessons be adequately serviced on an individual basis. 
Grouping of lessons, into units or partial servicing does not meet this 
requirement.
    (e) Each lesson must have a separate examination adequate in terms 
of lesson content.
    (f) The training of persons under a Department of Veterans Affairs 
contract or the fact that the United States is utilizing the facilities 
of the institution for training veterans shall not be used in any way to 
advertise the institution. References in the advertising media or 
correspondence of the institution shall be limited to a list of courses 
under Chapter 31, Title 38, United States Code, and shall not be 
directed or pointed specifically to veterans.
    (g) The rates, fees, and charges are not in excess of those charged 
nonveterans.
    (h) That payment will be made on a lesson completed basis in areas 
for assignments sent in by trainees and serviced during a pay period as 
established by the contract.
    (i) Payment will be made only once for each lesson even through it 
is necessary to service a lesson more than once.



871.211  Information concerning correspondence courses.

    Specific questions on correspondence courses as to the content of 
courses, academic credit, and entrance requirements for courses included 
in Department of Veterans Affairs contracts may be directed to the 
institutions offering the courses.



               Subpart 871.3--Education Program [Reserved]

[[Page 263]]



                     CHAPTER 9--DEPARTMENT OF ENERGY




                           (Parts 900 to 999)

  --------------------------------------------------------------------

                          SUBCHAPTER A--GENERAL
Part                                                                Page
901             Federal Acquisition Regulations System......         265
902             Definitions of words and terms..............         266
903             Improper business practices and personal 
                    conflicts of interest...................         266
904             Administrative matters......................         268
                   SUBCHAPTER B--ACQUISITION PLANNING
905             Publicizing contract actions................         273
906             Competition requirements....................         273
907             Acquisition planning........................         274
908             Required sources of supplies and services...         274
909             Contractor qualifications...................         280
911             Describing agency needs.....................         285
912

[Reserved]

          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
913             Simplified acquisition procedures...........         287
914             Sealed bidding..............................         287
915             Contracting by negotiation..................         288
916             Types of contracts..........................         301
917             Special contracting methods.................         302
                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
919             Small business programs.....................         307
922             Application of labor laws to Government 
                    acquisition.............................         308
923             Environment, conservation, occupational 
                    safety, and drug free workplace.........         311
925             Foreign acquisition.........................         313
926             Other socioeconomic programs................         315
             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
927             Patents, data, and copyrights...............         319

[[Page 264]]

928             Bonds and insurance.........................         334
931             Contract cost principles and procedures.....         335
932             Contract financing..........................         336
933             Protests, disputes, and appeals.............         339
             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING
935             Research and development contracting........         341
936             Construction and architect-engineer 
                    contracts...............................         343
937             Service contracting.........................         345
939             Acquisition of Federal information 
                    processing resources by contracting.....         345
941             Acquisition of utility services.............         347
                    SUBCHAPTER G--CONTRACT MANAGEMENT
942             Contract administration.....................         348
944             Subcontracting policies and procedures......         350
945             Government property.........................         351
947             Transportation..............................         355
949             Termination of contracts....................         355
950             Extraordinary contractual actions...........         355
951             Use of Government sources by contractors....         359
                     SUBCHAPTER H--CLAUSES AND FORMS
952             Solicitation provisions and contract clauses         360
             SUBCHAPTER I--AGENCY SUPPLEMENTARY REGULATIONS
970             DOE management and operating contracts......         400

[[Page 265]]



                          SUBCHAPTER A--GENERAL





PART 901--FEDERAL ACQUISITION REGULATIONS SYSTEM--Table of Contents




               Subpart 901.1--Purpose, Authority, Issuance

Sec.
901.101  Purpose.
901.102  Authority.
901.103  Applicability.
901.104  Issuance.
901.104-1  Publication and code arrangement.
901.104-2  Arrangement of regulations.
901.104-3  Copies.
901.105  OMB control numbers.

              Subpart 901.3--Agency Acquisition Regulations

901.301-70  Other issuances related to acquisition.

        Subpart 901.6--Contracting Authority and Responsibilities

901.601  General.
901.602-3  Ratification of unauthorized commitments.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  61 FR 41704, Aug. 9, 1996, unless otherwise noted.



               Subpart 901.1--Purpose, Authority, Issuance



901.101  Purpose.

    The Department of Energy Acquisition Regulation (DEAR) in this 
chapter establishes uniform acquisition policies which implement and 
supplement the Federal Acquisition Regulation (FAR).



901.102  Authority.

    The DEAR and amendments thereto are issued by the Procurement 
Executive pursuant to a delegation from the Secretary in accordance with 
the authority of section 644 of the Department of Energy Organization 
Act (42 U.S.C. 7254), section 205(c) of the Federal Property and 
Administrative Services Act of 1949, as amended, (40 U.S.C. 486(c)), and 
other applicable law.



901.103  Applicability.

    The FAR and DEAR apply to all DOE acquisitions of supplies and 
services which obligate appropriated funds unless otherwise specified in 
this chapter.



901.104  Issuance.



901.104-1  Publication and code arrangement.

    (a) The DEAR and its subsequent changes are published in the Federal 
Register, cumulative form in the Code of Federal Regulations, and a 
separate loose-leaf edition.
    (b) The DEAR is issued as chapter 9 of Title 48 of the Code of 
Federal Regulations.



901.104-2  Arrangement of regulations.

    (a) General. The DEAR is divided into the same parts, subparts, 
sections, subsections and paragraphs as is the FAR.
    (b) Numbering. The numbering illustrations at (FAR) 48 CFR 1.104-
2(b) apply to the DEAR, but the DEAR numbering will be preceded with a 9 
or a 90. Material which supplements the FAR will be assigned the numbers 
70 and up.



901.104-3  Copies.

    Copies of the DEAR published in the Federal Register or Code of 
Federal Regulations may be purchased from the Superintendent of 
Documents, Government Printing Office, Washington, DC 20402.



901.105  OMB control numbers.

    The Paperwork Reduction Act of 1980, Public Law 98-511, and the 
Office of Management and Budget's implementing regulations at 5 CFR part 
1320, require that reporting and record keeping requirements affecting 
10 or more members of the public be cleared by that Office. The OMB 
control number for the collection of information under 48 CFR chapter 9 
is 1910-4100, except for the following: Reporting and Recordkeeping 
requirements for Make-or-Buy Plans (see 48 CFR (DEAR) 970.5204-76)--OMB 
number 1910-5102; Reporting and

[[Page 266]]

Recordkeeping Requirements for Safety Management (see 48 CFR (DEAR) 
970.5204-2)--OMB number 1910-5103.
[61 FR 41704, Aug. 9, 1996, as amended at 62 FR 34861, June 27, 1997]



              Subpart 901.3--Agency Acquisition Regulations



901.301-70  Other issuances related to acquisition.

    In addition to the FAR and DEAR, there are other issuances which 
deal with acquisition. Among these are the Federal Property Management 
Regulations, the DOE Property Management Regulations, and DOE 
Directives.



        Subpart 901.6--Contracting Authority and Responsibilities



901.601  General.

    Contracting authority vests in the Secretary of Energy. The 
Secretary has delegated this authority to the Procurement Executive. The 
Procurement Executive has redelegated this authority to the Heads of 
Contracting Activities (HCA). These delegations are formal written 
delegations containing dollar limitations and conditions. Each HCA in 
turn makes formal contracting officer appointments within the 
contracting activity.



901.602-3  Ratification of unauthorized commitments. (DOE coverage--paragraph (b))

    (b) (2) The Procurement Executive is authorized to ratify an 
unauthorized commitment.
    (3) The ratification authority of the Procurement Executive in 
paragraph (b)(2) of this section is delegated to the Head of the 
Contracting Activity (HCA) for individual unauthorized commitments of 
$25,000 or under. The ratification authority of the HCA is nondelegable.



PART 902--DEFINITIONS OF WORDS AND TERMS--Table of Contents




    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).



                    Subpart 902.2--Definitions Clause



902.200  Definitions clause.

    As prescribed by FAR Subpart 2.2, insert the clause at FAR 52.202-1, 
Definitions, but modify it to limit the definition, at paragraph (a) of 
the clause, to encompass only the Secretary, Deputy Secretary, or Under 
Secretary of the Department of Energy and the Chairman, Federal Energy 
Regulatory Commission. The contracting officer shall also add a 
paragraph (d) (or (c) in case Alternate I is used), which defines 
``DOE'' as meaning the United States Department of Energy and ``FERC'' 
as meaning the Federal Energy Regulatory Commission.
[50 FR 12183, Mar. 27, 1985]



PART 903--IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST--Table of Contents




                        Subpart 903.1--Safeguards

Sec.
903.101  Standards of conduct.
903.101-3  Agency regulations.
903.104-11  Processing violations or possible violations under 
          procurement integrity.

      Subpart 903.2--Contractor Gratuities to Government Personnel

903.203  Reporting suspected violations of the Gratuities clause.
903.204  Treatment of violations.

        Subpart 903.3--Reports of Suspected Antitrust Violations

903.303  Reporting suspected antitrust violations.

                     Subpart 903.4--Contingent Fees

903.408-1  Responsibilities.

            Subpart 903.5--Other Improper Business Practices

903.502  Subcontractor kickbacks.

  Subpart 903.6--Contracts With Government Employees or Organizations 
                       Owned or Controlled by Them

903.603  Responsibilities of the contracting officer.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

[[Page 267]]


    Source:  49 FR 11940, Mar. 28, 1984, unless otherwise noted.



                        Subpart 903.1--Safeguards



903.101  Standards of conduct.



903.101-3  Agency regulations.

    Detailed rules applicable to the conduct of DOE employees are set 
forth in 10 CFR part 1010.
[49 FR 11940, Mar. 28, 1984, as amended at 60 FR 47307, Sept. 12, 1995]



903.104-11  Processing violations or possible violations under procurement integrity.

    (a) Except for Headquarters activities, the individual within DOE 
responsible for fulfilling the requirements of (FAR) 48 CFR 3.104-11(a) 
(1) and (2) relative to contracting officer conclusions on the impact of 
a violation or possible violation of the procurement integrity 
requirements shall be the legal counsel assigned direct responsibility 
for providing legal advice to the contracting office making the award or 
selecting the source. The legal counsel is the Chief Counsel for the 
Operations Offices or the Energy Technology Centers; the Counsel, or the 
Chief Counsel, for the Support Offices or the Naval Reactors Offices; 
and the General Counsel for the Power Administrations. For Headquarters 
activities, the individual designated to perform the responsibilities in 
(FAR) 48 CFR 3.104-11(a) (1) and (2) regarding questions of disclosure 
of proprietary or source selection information and certification matters 
is the Assistant General Counsel for Procurement and Financial 
Assistance. The designated individual for other questions regarding 
(FAR) 48 CFR 3.104-11(a) (1) and (2) for Headquarters activities is the 
Assistant General Counsel for General Law (Designated Agency Ethics 
Official).
[59 FR 11198, Mar. 10, 1994]



      Subpart 903.2--Contractor Gratuities to Government Personnel



903.203  Reporting suspected violations of the Gratuities clause.

    (a) Suspected violations of the Gratuities clause shall be reported 
to the Head of the Contracting Activity (HCA) in writing detailing the 
circumstances. The HCA will evaluate the report and, if the report 
appears to substantiate the allegations, the matter will be referred to 
the Procurement Executive for disposition.
[49 FR 11940, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



903.204  Treatment of violations.

    Apparent violations will be processed in accordance with the 
debarment and suspension rules set forth at Title 10, part 1035, of the 
Code of Federal Regulations.



        Subpart 903.3--Reports of Suspected Antitrust Violations



903.303  Reporting suspected antitrust violations.

    (a) Potential anti-competitive practices, such as described in FAR 
3.301, and antitrust law violations as described in FAR 3.303, evidenced 
in bids or proposals, shall be reported to the Office of General Counsel 
through the Head of the Contracting Activity with a copy to the 
Procurement Executive. The Office of General Counsel will provide 
reports to the Attorney General, as appropriate.
[50 FR 12183, Mar. 27, 1985, as amended at 59 FR 9104, Feb. 25, 1994]



                     Subpart 903.4--Contingent Fees



903.408-1  Responsibilities.

    (b) Each Standard Form 119 completed in connection with a DOE 
contract, together with other relevant information, shall be reviewed by 
Counsel prior to the initiation of appropriate action.



            Subpart 903.5--Other Improper Business Practices



903.502  Subcontractor kickbacks.

    (b) Contracting officers shall report suspected violations of the 
Anti-Kickback Act through the Head of the Contracting Activity, or 
designee, to the Office of General Counsel.

[[Page 268]]



  Subpart 903.6--Contracts With Government Employees or Organizations 
                       Owned or Controlled by Them



903.603  Responsibilities of the contracting officer.

    (a) When the needs of the Government cannot be reasonably supplied 
by sources other than employees of the Government or sources which are 
substantially owned or controlled by Government employees, the 
contracting officer, in accordance with FAR 48 CFR 3.602, may submit, 
through the HCA, a request to the Procurement Executive, with 
appropriate justification, for approval of an exception to the 
prohibitions contained in FAR 3.601.
[49 FR 11940, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



PART 904--ADMINISTRATIVE MATTERS--Table of Contents




   Subpart 904.4--Safeguarding Classified Information Within Industry

Sec.
904.401  Definitions.
904.402  General.
904.404  Contract clause.

                        Subpart 904.6 [Reserved]

               Subpart 904.7--Contractor Records Retention

904.702  Applicability.

                      Subpart 904.8--Contract Files

904.803  Contents of contract files.
904.804-1  Closeout by the office administering the contract.
904.805  Disposal of contract files.

     Subpart 904.70--Foreign Ownership, Control, or Influence Over 
                               Contractors

904.7000  Purpose.
904.7001  Applicability.
904.7002  Definitions.
904.7003  Disclosure of foreign ownership, control, or influence.
904.7004  Findings, determination, and contract award or termination.
904.7005  Solicitation provision and contract clause.

 Subpart 904.71--Prohibition on Contracting (National Security Program 
                               Contracts)

904.7100  Scope of subpart.
904.7101  Definitions.
904.7102  Waiver by the Secretary.
904.7103  Solicitation provision and contract clause.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11941, Mar. 28, 1984, unless otherwise noted.



   Subpart 904.4--Safeguarding Classified Information Within Industry



904.401  Definitions.

    Classified Information means any information or material that is 
owned by, produced by or for, or is under the control of the United 
States Government, and determined pursuant to provisions of Executive 
Order 12356, April 2, 1982 (47 FR 14874, April 6, 1982), or prior 
orders, or as authorized under the Atomic Energy Act of 1954, as 
amended, to require protection against unauthorized disclosure, and is 
so designated.
    Restricted Data means data which is defined in section 11, of the 
Atomic Energy Act of 1954, as amended, as ``all data concerning: (1) 
Design, manufacture, or utilization of atomic weapons; (2) the 
production of special nuclear material; or (3) the use of special 
nuclear material in the production of energy, but shall not include data 
declassified or removed from the Restricted Data category pursuant to 
section 142.''
[49 FR 11941, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



904.402  General.

    (a) The basis of DOE's security requirements is the Atomic Energy 
Act of 1954, as amended.
    (b) DOE security regulations. DOE regulations concerning national 
security information are codified at 10 CFR part 1045.
[49 FR 11941, Mar. 28, 1984, as amended at 60 FR 47307, Sept. 12, 1995]



904.404  Contract clause.

    (d) The security clauses to be used in DOE contracts are found at 
952.204. They are:

[[Page 269]]

    (1) Security, 952.204-2. This clause is required in contracts under 
section 31 (research assistance) or 41 (ownership and operation of 
production facilities) of the Atomic Energy Act of 1954, as amended, and 
in other contracts and subcontracts, the performance of which involves 
or is likely to involve classified information. The DOE system is 
separate from that of the Department of Defense and the DEAR clause 
shall be used instead of that at FAR 52.204-2.
    (2) Classification, 952.204-70. This clause is to be used in all 
contracts which involve classified information.
    (3) Sensitive foreign nation controls, 952.204-71. This clause is 
required in unclassified research contracts which may involve making 
unclassified information about nuclear technology available to certain 
sensitive foreign nations. The contractor shall be provided at the time 
of award the listing of nations included in DOE 1240.2 (see current 
version.), Attachment 3, and any subsequent changes. (The attachment 
referred to in the clause shall set forth the applicable requirements of 
the DOE regulations on dissemination of unclassified published and 
unpublished technical information to foreign nations.)
    (4) Disclosure of information, 952.204-72. This clause should be 
used in place of the clauses entitled ``Security'' and 
``Classification'' in contracts with educational institutions for 
research work performed in their own institute facilities that are not 
likely to produce classified information.
[49 FR 11941, Mar. 28, 1984; 49 FR 38949, Oct. 2, 1984, as amended at 54 
FR 27646, June 30, 1989; 59 FR 24358, May 11, 1994]



                        Subpart 904.6 [Reserved]



               Subpart 904.7--Contractor Records Retention



904.702  Applicability.

    (b) Contracts containing the Safety and Health clause at 952.223-71, 
the Radiation Protection and Nuclear Criticality clause at 952.223-72, 
or the Nuclear Safety clause at 952.223-74 must also include the 
Preservation of Individual Occupational Radiation Exposure Records 
clause at 952.223-75 which will necessitate retention of records in 
accordance with schedules contained in applicable DOE Directives in the 
records management series, rather than those found at FAR 4.7.
[49 FR 11941, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994; 60 
FR 47307, Sept. 12, 1995; 62 FR 2312, Jan. 16, 1997]



                      Subpart 904.8--Contract Files



904.803  Contents of contract files.

    (a) (29) The record copy of the Individual Procurement Action Report 
shall be included in the file section containing procurement management 
reports.



904.804-1  Closeout by the office administering the contract.

    (a) The Head of the Contracting Activity shall ensure that necessary 
procedures and milestone schedules are established to meet the 
requirements of FAR 4.804-1, and that resources are applied to effect 
the earliest practicable deobligation of excess funds and the timely 
closeout of all contract files which are physically completed or 
otherwise eligible for closeout action.
    (b) Quick closeout procedures for cost reimbursable and other than 
firm fixed price type contracts are covered under 942.708.



904.805  Disposal of contract files.

    Contract files shall be disposed of in accordance with applicable 
DOE Order 1324.2. (See current version.)
[49 FR 11941, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



     Subpart 904.70--Foreign Ownership, Control, or Influence Over 
                               Contractors



904.7000  Purpose.

    This subpart sets forth the Department of Energy policies and 
procedures regarding foreign ownership, control, or influence (FOCI) 
over contractors. The procedures are designed to protect against an 
undue risk to the common defense and security which may result if 
classified information or special nuclear material is made available to 
DOE contractors or subcontractors

[[Page 270]]

who are owned, controlled, or influenced by foreign governments, 
individuals, or organizations. The procedures require certain offeror(s) 
and contractors/subcontractors to submit information which will help DOE 
to determine whether award of a contract to a firm, or continued 
performance of a contract by a firm, may pose an undue risk to the 
common defense and security because of the foreign influence.
[49 FR 11941, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



904.7001  Applicability.

    The provisions of this subpart shall apply to all offeror(s), 
contractors, and subcontractors who will or do have access to classified 
information or a significant quantity of special nuclear material as 
defined in 10 CFR part 710. In this subpart, the term ``contractor'' 
shall also mean subcontractor at any tier, the term ``contract'' shall 
also mean subcontract at any tier, and the term ``special nuclear 
material'' shall also mean significant quantity of special nuclear 
material as defined in 10 CFR part 710.
[49 FR 11941, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



904.7002  Definitions.

    Contracting officer means the DOE contracting officer.
    Foreign interest means any of the following:
    (1) Foreign government or foreign government agency or 
instrumentality thereof;
    (2) Any form of business enterprise organized under the laws of any 
country other than the United States or its possessions;
    (3) Any form of business enterprise organized or incorporated under 
the laws of the U.S., or a State or other jurisdiction within the U.S. 
which is owned, controlled, or influenced by a foreign government, 
agency, firm, corporation, or person, or
    (4) Any person who is not a U.S. citizen.
    Foreign ownership, control, or influence means the situation where 
the degree of ownership, control, or influence over an offeror(s) or a 
contractor by a foreign interest is such that a reasonable basis exists 
for concluding that compromise of classified information or special 
nuclear material may possibly result.
[49 FR 11941, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



904.7003  Disclosure of foreign ownership, control, or influence.

    (a) If a contract requires a contractor to have access to classified 
information or a significant quantity of special nuclear material, the 
DOE must determine whether access to the information or material by a 
contractor who is or may be subject to FOCI may pose an undue risk to 
the common defense and security before a contract can be awarded.
    (b) If during the performance of a contract, the contractor comes 
under FOCI, then the DOE must determine whether any further access to 
the classified information or special nuclear material may pose an undue 
risk to the common defense and security through the possible compromise 
of that information or material. If the DOE determines that such a 
threat or potential threat exists, the contracting officer shall 
consider the alternatives of negotiating an acceptable method of 
isolating the foreign interest which owns, controls, or influences the 
contractor or terminating the contract.
    (c) It is essential for the DOE to obtain information about FOCI 
which is sufficient to help the Department determine whether award of a 
contract to a person or firm, or the continued performance of a contract 
by a person or firm, may pose undue risk to the common defense and 
security. Therefore, the provision specified at 952.204-73 shall be 
included in solicitations that involve offeror(s) or contractors that 
are subject to 904.7001.
    (d) The contracting officer shall not award or extend any contract 
subject to this subpart, exercise any options under a contract, modify 
any contracts subject to this subpart, or approve or consent to a 
subcontract subject to this subpart unless:
    (1) The contractor provides the information required by the 
solicitation provision at 48 CFR 952.204-73, and

[[Page 271]]

    (2) The contracting officer has made a positive determination in 
accordance with 48 CFR 904.7004.
[49 FR 11941, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994; 62 
FR 42073, Aug. 5, 1997]



904.7004  Findings, determination, and contract award or termination.

    (a) Based on the information disclosed by the offeror(s) or 
contractor, and after consulting with the DOE Office of Safeguards and 
Security, the contracting officer must determine that award of a 
contract to an offeror(s) or continued performance of a contract by a 
contractor will not pose an undue risk to the common defense and 
security. The contracting officer need not prepare a separate finding 
and determination addressing FOCI; however, the memorandum of 
negotiation shall include a discussion of the applicability of this 
subpart and the resulting determination.
    (b) In those cases where FOCI does exist, and the DOE determines 
that an undue risk to the common defense and security may exist, the 
offeror(s) or contractor shall be requested to propose within a 
prescribed period of time a plan of action to avoid or mitigate the 
foreign influences by isolation of the foreign interest.
    (c) The types of plans that a contractor can propose are: measures 
which provide for physical or organizational separation of the facility 
or organizational component containing the classified information or 
special nuclear material; modification or termination of agreements with 
foreign interests; diversification or reduction of foreign source 
income; assignment of specific security duties and responsibilities to 
board members or special executive level committees; or any other 
actions to negate or reduce FOCI to acceptable levels. The plan of 
action may vary with the type of foreign interest involved, degree of 
ownership, and information involved so that each plan must be negotiated 
on a case by case basis. If the offeror(s) or contractor and the DOE 
cannot negotiate a plan of action that isolates the offeror(s) or 
contractor from FOCI satisfactory to the DOE, then the offeror(s) shall 
not be considered for contract award and affected existing contracts 
with a contractor shall be terminated.
[49 FR 11941, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



904.7005  Solicitation provision and contract clause.

    (a) The contracting officer shall insert the provision at 48 CFR 
952.204-73, Foreign Ownership, Control, or Influence over Contractor, in 
all solicitations for contracts subject to 48 CFR 904.7001.
    (b) The contracting officer shall insert the clause at 952.204-74, 
Foreign Ownership, Control, or Influence Over Contractor, in new 
contracts and contract modifications to existing contracts subject to 
904.7001.
[49 FR 11941, Mar. 28, 1984, as amended at 62 FR 42074, Aug. 5, 1997]



 Subpart 904.71--Prohibition on Contracting (National Security Program 
                               Contracts)

    Source:  58 FR 59684, Nov. 10, 1993, unless otherwise noted.



904.7100  Scope of subpart.

    This subpart implements section 836 of the Fiscal Year 1993 Defense 
Authorization Act (Pub. L. 102-484) which prohibits the award of a 
Department of Energy contract under the national security program to a 
company owned by an entity controlled by a foreign government if it is 
necessary for that company to be given access to information in a 
proscribed category of information in order to perform the contract.



904.7101  Definitions.

    Effectively owned or controlled means that a foreign government or 
an entity controlled by a foreign government has the power, either 
directly or indirectly, whether exercised or exercisable, to control or 
influence the election or appointment of the Offeror's officers, 
directors, partners, regents, trustees, or a majority of the Offeror's 
board of directors by any means, e.g., ownership, contract, or operation 
of law.
    Entity controlled by a foreign government means any domestic or 
foreign organization or corporation that is effectively owned or 
controlled by a foreign

[[Page 272]]

government or any individual acting on behalf of a foreign government. 
See 925.7 for a statement of the prohibition.
    Foreign government means any governing body organized and existing 
under the laws of any country other than the United States and its 
possessions and trust territories and any agent or instrumentality of 
that government.
    Proscribed information means--
    (1) Top Secret information;
    (2) Communications Security (COMSEC) information, except classified 
keys used to operate secure telephone units (STU IIIs);
    (3) Restricted Data, as defined in the Atomic Energy Act of 1954, as 
amended;
    (4) Special Access Program (SAP) information; or,
    (5) Sensitive Compartmented Information (SCI).



904.7102  Waiver by the Secretary.

    (a) The Secretary of Energy may waive this prohibition, pursuant to 
10 U.S.C. 2536(b), if the Secretary determines that waiver is essential 
to the national security interests of the United States. Any request for 
such a waiver shall address:
    (1) Identification of the proposed awardee and description of the 
foreign ownership;
    (2) Description of the procurement and performance requirements;
    (3) Description of the national security interests involved and the 
ways award of the contract would promote those interests;
    (4) The availability of other entities to perform the work; and,
    (5) A description of alternate means available to satisfy the 
requirement.
    (b) Any request for such a waiver shall be forwarded by the Head of 
the Contracting Activity to the Office of Clearance and Support, within 
the Headquarters procurement organization. That office will coordinate 
such requests with the Program Assistant Secretary, the Office of 
Intelligence and National Security, the Office of General Counsel, and 
the Procurement Executive prior to seeking approval of the Secretary.



904.7103  Solicitation provision and contract clause.

    (a) Any solicitation, including those under simplified acquisition 
procedures, for a contract under the national security program which 
will require acess to proscribed information shall include the provision 
at 48 CFR 952.204-73 with its Alternate I.
    (b) Any contract, including those awarded under simplified 
acquisition procedures, under the national security program which 
require access to proscribed information to enable performance, shall 
include the clause at 952.204-74.
[58 FR 59684, Nov. 10, 1993, as amended at 61 FR 21976, May 13, 1996; 62 
FR 42074, Aug. 5, 1997]

[[Page 273]]



                   SUBCHAPTER B--ACQUISITION PLANNING





PART 905--PUBLICIZING CONTRACT ACTIONS--Table of Contents




                   Subpart 905.5--Paid Advertisements

Sec.
905.502  Authority.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).



                   Subpart 905.5--Paid Advertisements



905.502  Authority.

    (a) Newspapers. When it is deemed necessary to use paid 
advertisements in newspapers and trade journals, written authority for 
such publication shall be obtained from the Head of the Contracting 
Activity or designee.
[49 FR 11943, Mar. 28, 1984]



PART 906--COMPETITION REQUIREMENTS--Table of Contents




                Subpart 906.1--Full and Open Competition

Sec.
906.102  Use of competitive procedures.

   Subpart 906.2--Full and Open Competition After Exclusion of Sources

906.202  Establishing or maintaining alternative sources.

           Subpart 906.3--Other Than Full and Open Competition

906.304  Approval of the justification.

                  Subpart 906.5--Competition Advocates

906.501  Requirement.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  50 FR 12183, Mar. 27, 1985, unless otherwise noted.



                Subpart 906.1--Full and Open Competition



906.102  Use of competitive procedures.

    (d) Other competitive procedures.
    (1) Professional architect-engineer services shall be negotiated in 
accordance with subpart 936.6 and FAR Subpart 36.6.
    (4) Competitive selection of research proposals for award received 
in response to a Program Research and Development Announcement (See 
subpart 917.73 and part 935).
    (5) Competitive selection for award of proposals offered in response 
to program opportunity notices (See subpart 917.72).



   Subpart 906.2--Full and Open Competition After Exclusion of Sources



906.202  Establishing or maintaining alternative sources.

    (b)(1) Every proposed contract action under the authority of FAR 
6.202(a) shall be supported by a determination and finding (D&F) signed 
by the Procurement Executive.



           Subpart 906.3--Other Than Full and Open Competition



906.304  Approval of the justification.

    (c) Class justifications within the delegated authority of a Head of 
the Contracting Activity may be approved for:
    (1) Contracts for electric power or energy, gas (natural or 
manufactured), water, or other utility services when such services are 
available from only one source;
    (2) Contracts under the authority cited in FAR 6.302-4 or 6.302-5; 
or
    (3) Contracts for educational services from nonprofit institutions. 
Class justifications for classes of actions that may exceed $10,000,000 
require the approval of the Procurement Executive.



                  Subpart 906.5--Competition Advocates



906.501  Requirement.

    The Secretary of Energy has delegated the authority for appointment 
of the agency and contracting activity competition advocates to the 
Procurement Executive. The Procurement Executive has delegated authority 
to the Head of the Contracting Activity to appoint contracting activity 
competition

[[Page 274]]

advocates. Procedural guidance is provided in internal DOE Directives.



PART 907--ACQUISITION PLANNING--Table of Contents




         Subpart 907.3--Contractor Versus Government Performance

Sec.
907.307  Appeals.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11944, Mar. 28, 1984, unless otherwise noted.



         Subpart 907.3--Contractor Versus Government Performance



907.307  Appeals.

    An appeal of a decision to convert to contract or to continue in-
house performance may be made by an affected party. Appeals shall be 
made in writing, be based only on specific alleged material deviation 
(or deviations),from OMB Circular A-76, and be supported by appropriate 
documentation. Appeals must be delivered within 15 working days of the 
announced decision, to the contracting officer. The contracting officer 
shall process any such appeal in accordance with internal Departmental 
procedures.



PART 908--REQUIRED SOURCES OF SUPPLIES AND SERVICES--Table of Contents




       Subpart 908.8--Acquisition of Printing and Related Supplies

Sec.
908.802  Policy.

                Subpart 908.11--Leasing of Motor Vehicles

908.1102  Presolicitation requirements.
908.1104  Contract clauses.
908.1170  Leasing of fuel-efficient vehicles.

              Subpart 908.71--Acquisition of Special Items

908.7100  Scope of subpart.
908.7101  Motor vehicles.
908.7101-1  Scope of section.
908.7101-2  Consolidated acquisition of new vehicles by General Services 
          Administration.
908.7101-3  Direct acquisition.
908.7101-4  Replacement of motor vehicles.
908.7101-5  Used vehicles.
908.7101-6  Acquisition of fuel-efficient vehicles.
908.7101-7  Government license tags.
908.7102  Aircraft.
908.7103  Office machines.
908.7104  Office furniture and furnishings.
908.7105  Filing cabinets.
908.7106  Security cabinets.
908.7107  Alcohol.
908.7108  Helium.
908.7109  Fuels and packaged petroleum products.
908.7110  Coal.
908.7111  Arms and ammunition.
908.7112  Materials handling equipment replacement standards.
908.7113  Calibration services.
908.7114  Wiretapping and eavesdropping equipment.
908.7115  Forms.
908.7116  Electronic data processing tape.
908.7117  Tabulating machine cards.
908.7118  Rental of post office boxes.
908.7119-908.7120  [Reserved]
908.7121  Special materials.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11945, Mar. 28, 1984, unless otherwise noted.



       Subpart 908.8--Acquisition of Printing and Related Supplies



908.802  Policy. (DOE coverage--paragraph (b))

    (b) Inclusion of printing requirements (limited exceptions are set 
forth in paragraphs 35-2 through 35-4 of the Government Printing and 
Binding Regulations) in contracts for supplies and services is 
prohibited unless specifically approved by the Director, Office of 
Administrative Services, Headquarters. Contracting officers shall insert 
the clause at 48 CFR 952.208-70.
[61 FR 41705, Aug. 9, 1996]



                Subpart 908.11--Leasing of Motor Vehicles

    Source:  61 FR 41705, Aug. 9, 1996, unless otherwise noted.



908.1102  Presolicitation requirements. (DOE coverage--paragraph (a))

    (a)(4) Commercial vehicle lease sources may be used only when the 
General Services Administration (GSA) has advised that it cannot furnish 
the vehicle(s) through the Interagency

[[Page 275]]

Motor Pool System and it has been determined that the vehicle(s) are not 
available through the GSA Consolidated Leasing Program.



908.1104  Contract clauses. (DOE coverage--paragraph (e))

    (e) The clause at 48 CFR 952.208-7, Tagging of Leased Vehicles, 
shall be inserted whenever a vehicle(s) is to be leased over 60 days, 
except for those vehicles exempted by (FPMR) 41 CFR 101-38.6.



908.1170  Leasing of fuel-efficient vehicles.

    (a) All sedans and station wagons and certain types of light trucks, 
as specified by GSA, that are acquired by lease for 60 continuous days 
or more for official use by DOE or its authorized contractors, are 
subject to the requirements of the Energy Policy and Conservation Act of 
1975 (EPCA), Public Law 94-163 and of Executive Order 12003 and 
subsequent implementing regulations.
    (b) Leased vehicles will meet the miles-per-gallon criteria of, and 
be incorporated in, the approved plan of the fiscal year in which leases 
are initiated, reviewed, extended, or increased in scope. Vehicle leases 
will specify the vehicle model type to be provided.



              Subpart 908.71--Acquisition of Special Items



908.7100  Scope of subpart.

    This subpart sets forth requirements and procedures for the 
acquisition of special items by DOE and contractors authorized to use 
special sources of supply to the extent indicated herein.



908.7101  Motor vehicles.



908.7101-1  Scope of section.

    Acquisitions by purchase of motor vehicles shall be in accordance 
with this section.



908.7101-2  Consolidated acquisition of new vehicles by General Services Administration.

    (a) New vehicles shall be procured in accordance with FPMR 41 CFR 
101-25.304, 101-26.501, and 101-38.13, and DOE-PMR 41 CFR 109-25.304, 
109-38.13, and 109-38.51.
    (b) Orders for all motor vehicles shall be submitted on GSA Form 
1781, Motor Vehicle Requisition--Delivery Order--Invoice, in accordance 
with FPMR 41 CFR 101-26.501. Requisitions for sedans, station wagons, 
and certain light trucks as specified by GSA, should contain a 
certification that the acquisition is in conformance with Pub. L. 94-
163, and Executive Order 12003 and 12375 and subsequent implementations.
    (c) The schedule of dates for submission of orders is contained in 
FPMR 41 CFR 101-26.501-4. The Heads of Contracting Activities shall 
consolidate and submit their requirements for passenger automobiles 
early in the fiscal year. Requisitions for sedans, station wagons and 
certain types of light trucks shall be submitted through Headquarters as 
outlined in 908.7101-6. Requisitions for all other types of vehicles 
shall be submitted directly to GSA.
[49 FR 11945, Mar. 28, 1984; 49 FR 38949, Oct. 2, 1984, as amended at 59 
FR 9104, Feb. 25, 1994]



908.7101-3  Direct acquisition.

    Vehicles may be acquired by DOE activities directly rather than 
through GSA when a waiver has been granted by GSA. A copy of the 
activity's request to GSA for a waiver shall be forwarded to the 
Director, Office of Property Management, within the Headquarters 
procurement organization. In those cases involving general purpose 
vehicles where GSA refuses to grant a waiver and where it is believed 
that acquisition through GSA would adversely affect or otherwise impair 
the program, authority for direct acquisition shall be obtained from the 
above-mentioned Headquarters official, prior to acquisition. In the 
acquisition of special purpose vehicles for use by DOE and its 
authorized contractors, the Head of the Contracting Activity may 
authorize direct purchases. The purchase price for sedans and station 
wagons, shall not exceed any statutory limitation in effect at the time 
the acquisition is

[[Page 276]]

made. (See DOE-PMR 41 CFR 109-38.5102-4).
[49 FR 11945, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984, as amended at 59 
FR 9104, Feb. 25, 1994]



908.7101-4  Replacement of motor vehicles.

    (a) The replacement of motor vehicles shall be in accordance with 
the replacement standards prescribed in FPMR 41 CFR 101-38.9 and DOE-PMR 
41 CFR 109-38.9.
    (b) The Heads of Contracting Activities may arrange to sell, as 
exchange sales, used motor vehicles being replaced and to apply the 
proceeds to the purchase of similar new vehicles. However, in the event 
personnel are not available to make such sales, or it is in the best 
interest of the DOE office, GSA may be requested to sell the used 
vehicles.
[49 FR 11945, Mar. 28, 1984, as amended at 59 FR 9104, Feb. 25, 1994]



908.7101-5  Used vehicles.

    Normally, DOE does not purchase or authorize contractors to purchase 
used vehicles. However, the Heads of Contracting Activities may 
authorize the purchase of used vehicles where justified by special 
circumstances; e.g., when new vehicles are in short supply, the vehicles 
are to be used for experimental or test purposes, or the vehicles are 
acquired from exchange sale. In accordance with DOE-PMR 41 CFR 109-
38.5102, the statutory passenger vehicle allocation requirements for DOE 
shall apply to any purchase of used vehicles except in the case of 
vehicles to be used exclusively for experimental or test purposes.
[49 FR 11945, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984, as amended at 59 
FR 9104, Feb. 25, 1994]



908.7101-6  Acquisition of fuel-efficient vehicles.

    (a) All purchases of sedans and station wagons, and certain types of 
light trucks as specified by GSA, are subject to the requirements of the 
Energy Policy and Conservation Act of 1975 (EPCA), Pub. L. 94-163, and 
of Executive Orders 12003 and 12375 and subsequent implementing 
regulations. Accordingly, the Director of Administration and the Heads 
of Contracting Activities will submit annually to the Director, Office 
of Property Management, within the Headquarters procurement 
organization, for approval, a forecast of plans for the purchase of such 
vehicles during the fiscal year. Such forecast shall be submitted so as 
to arrive at Headquarters on or before December 1 of each year. 
Additionally, the original and 2 copies of requisitions (GSA form 1781) 
for purchase of such vehicles shall also be forwarded to the above 
official for review and certification/approval prior to submission to 
GSA. All such documentation will be reviewed by this official and a 
determination made as to conformance with applicable annual forecasts 
and pertinent public laws and their implementations. (See DOE-PMR 41 CFR 
109-38.13.)
    (b) Sedans, station wagons, and light trucks requisitioned according 
to an approved forecast, but not contracted for by GSA until the 
subsequent fiscal year, will be included in the acquisition plan for the 
miles-per-gallon criteria of the year in which GSA signs the purchase 
contract along with the new vehicles planned for acquisition that year.
[49 FR 11945, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984, as amended at 59 
FR 9104, Feb. 25, 1994]



908.7101-7  Government license tags.

    (a) Government license tags shall be procured and assignments 
recorded by DOE offices in accordance with FPMR 41 CFR 101-38.303.
    (b) The letter ``E'' has been designated as the prefix symbol for 
all DOE official license tags. Assignments of specific ``blocks'' of tag 
numbers and the maintenance of tag assignment records, are performed by 
the Director, Office of Property Management, within the Headquarters 
procurement organization. Assignments of additional ``blocks'' of tag 
numbers will be made upon receipt of written requests from field 
offices.
    (c) Special license tags for security purposes shall be purchased in 
accordance with state and local laws, regulations, and procedures.
    (d) In the District of Columbia, official Government tags shall be 
obtained

[[Page 277]]

from the Department of Transportation, Motor Vehicles Services Branch, 
District of Columbia, for all motor vehicles (except vehicles exempt for 
security purposes) based or housed in the District.
    (e) See DOE-PMR 41 CFR 109-38.3 and 109-38.6 for additional 
guidance.
[49 FR 11945, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984, as amended at 59 
FR 9104, Feb. 25, 1994]



908.7102  Aircraft.

    Acquisition of aircraft shall be in accordance with DOE-PMR 41 CFR 
109-38.5205.



908.7103  Office machines.

    Acquisitions of office machines by DOE offices and its authorized 
contractors shall be in accordance with FPMR 41 CFR 101-25.104, 101-
25.302, 101-25.302-3, 101-25.302-4, and 101-25.302-6, and 101-25.403, 
and DOE-PMR 41 CFR 109-25.302, 109-25.302-3, and 109-25.4.



908.7104  Office furniture and furnishings.

    Acquisitions of office furniture and furnishings by DOE offices 
shall be in accordance with FPMR 41 CFR 101-25.104, 101-25.302, 101-
25.302-1, 101-25.302-5, 101-25.302-7, and 101-25.302-8, 101-25.404 and 
101-26.505, and DOE-PMR 41 CFR 109-25.302, 109-25.302-1, and 109-25.350.



908.7105  Filing cabinets.

    Acquisitions of filing cabinets shall be in accordance with FPMR 41 
CFR 101-26.308 and 101-25.302-2 and DOE-PMR 41 CFR 109-25.302-2.
[49 FR 11945, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984]



908.7106  Security cabinets.

    (a) Acquisitions of security cabinets shall be in accordance with 
FPMR 41 CFR 101-26.507 and the ``prerequisites to ordering'' criteria 
contained in FPMR 41 CFR 101-25.302-2 and DOE-PMR 41 CFR 109-25.302-2.
    (b) Fixed-price prime contractors and lower tier subcontractors may 
use GSA acquisition sources for security cabinets in accordance with 
FPMR 41 CFR 101-26.407 and FAR 51.
[49 FR 11945, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984]



908.7107  Alcohol.

    (a) This section covers (1) Bureau of Alcohol, Tobacco and Firearms, 
(ATF), Treasury Department, alcohol regulations applicable to DOE, (2) 
delegations of authority to submit applications to purchase tax-free 
alcohol or specially denatured alcohol, and (3) purchases of alcohol by 
DOE or authorized contractors. To the fullest extent practicable, 
alcohol for use by DOE or its cost-type contractors shall be procured on 
a tax-free basis.
    (b) ATF regulations relating to the acquisition and use of alcohol 
free of tax, by Government agencies, are set forth in 26 CFR 213.141-
213.146. Copies of excerpts from these regulations may be secured from 
the Bureau of Alcohol, Tobacco and Firearms, Department of Treasury, 
Washington, DC 20226. These regulations shall be followed in the 
acquisition of alcohol.
    (c) ATF Form 1444/1486, ``Tax Free Spirits or Specially Denatured 
Spirits for Use of United States,'' shall be used for acquisitions of 
specially denatured alcohol and ethyl alcohol. Section I of the form is 
the application for permission to acquire and Section II is the permit. 
If acquisition from more than one warehouse is desirable, separate 
applications must be made for withdrawal from each warehouse. When 
permits are no longer required, they should be forwarded to the Bureau 
of Alcohol, Tobacco and Firearms for cancellation. Alcohol procured by 
use of the ATF form referred to in this subsection shall be used 
exclusively on DOE work.
    (d) The Procurement Executive has been authorized to sign and 
delegate to others authority to sign applications under Bureau of 
Alcohol, Tobacco and Firearms regulations relating to the acquisition 
and use of alcohol free of tax. Specific DOE personnel have been 
delegated authority to execute Part I of Form 1444/1486 by letters to 
the Director, Bureau of Alcohol, Tobacco and Firearms without power of 
redelegation. Copies of such letters have been

[[Page 278]]

furnished to field offices. Only the individuals so authorized shall 
execute Section I of these forms. Requests by field offices for new 
authorizations or changes to existing authorizations shall be submitted 
by letter to the Procurement Executive.
    (e) Applications on the ATF Form 1444/1486 shall be executed in 
duplicate by an authorized DOE official and mailed directly to the 
address on the application. Only one permit will be provided to each 
field organization. Due to the numerous locations managed by field 
operations offices, the exact shipping address need not be shown in 
block 3 of the form. Shipments, however, must be addressed to the 
``Department of Energy at various locations within the United States''. 
The ATF will assign the application a permit number and return it to the 
requestor. Distribution of certified copies shall be controlled and each 
holder of a certified copy recorded.
    (f) Annually, the Bureau of Alcohol, Tobacco and Firearms publishes 
printed lists of Distilled Spirits Plants, Bonded Warehouses and 
Denaturing Plants Authorized to Operate. Copies of these lists and 
supplies of Form 1444/1486 may be secured by written request to the 
Director, Bureau of Alcohol, Tobacco and Firearms, Special Operations 
Branch, Washington, DC 20226.
    (g) A signed copy of the permit shall accompany the original 
purchase order issued to the plant or warehouse, where it shall be 
retained or returned with the shipment. Subsequent orders shall refer to 
the permit on file in the plant or warehouse if it was retained.
    (h) When alcohol is shipped, the shipper prepares the required form 
as specified by Bureau of Alcohol, Tobacco and Firearms regulations and 
forwards them to the consignee. Upon receipt of the receiving report 
covering the shipment, the officer who signed the purchase order shall 
execute the certificate of receipt and forward it to the appropriate 
Regional Director, Bureau of Alcohol, Tobacco and Firearms. The carrier 
transporting the alcohol shall also be given a receipt as specified by 
Bureau of Alcohol, Tobacco and Firearms regulations.
    (i) Abandoned and forfeited alcohol which has come into the custody 
or control of a Federal agency may be obtained by following the 
procedure set forth in FPMR 41 CFR 101-48.1
[49 FR 11945, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



908.7108  Helium.

    (a) Acquisitions of helium by DOE and its authorized contractors 
shall be in accordance with this section.
    (b) The Helium Act (Pub. L. 86-777, as amended (50 U.S.C. 167(d)) 
provides that, to the extent that supplies are readily available, 
whether in gaseous or liquid form, DOE shall purchase all major 
requirements of helium from the Secretary of Interior, Bureau of Mines, 
or from the Bureau of Mines distribution contractors eligible to sell 
Bureau of Mines helium to Federal agencies and their users in accordance 
with 30 CFR part 602.
    (c)(1) Purchases may be made directly from the Bureau of Mines by 
forwarding a purchase order in duplicate to: Bureau of Mines, Division 
of Helium Operations, 1100 South Fillmore Street, Amarillo, Texas 79101.
    (2) Purchases may be made from those commercial firms listed in the 
Bureau of Mines as eligible to sell helium to Federal users.
    (i) The purchase document shall contain the following statement: 
``Helium furnished under this contract shall be Bureau of Mines 
Helium.''
    (ii) A copy of each acquisition document shall be furnished to the 
address in paragraph (c)(1) of this section.
[49 FR 11945, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



908.7109  Fuels and packaged petroleum products.

    Acquisitions of fuel and packaged petroleum products by DOE offices 
shall be in accordance with FPMR 41 CFR 101-26.602. When contractors are 
authorized, consistent with 951, to acquire such products from Defense 
sources, they shall do so in accordance with FPMR 41 CFR 101-26.602.



908.7110  Coal.

    DOE offices and authorized contractors may participate in the 
Defense Fuel Supply Center (DFSC) coal contracting program for carload 
or larger

[[Page 279]]

lots. If participation is desired, estimates shall be submitted to DFSC 
in accordance with FPMR 41 CFR 101-26.602.



908.7111  Arms and ammunition.

    Pursuant to 10 U.S.C. 4655, the Secretary of the Army is authorized 
to furnish arms, suitable accouterments for use therewith, and 
ammunition for the protection of public money and property.
    (a) The Department of the Army has granted clearance for Federal 
agencies to procure, without further reference to or clearance from that 
Department, all arms and ammunition of types which are not peculiar to 
the military services, and which are readily procurable in the civilian 
market.
    (b) Acquisition of arms and ammunition readily procurable in the 
civilian market shall be made in accordance with regular acquisition 
procedures.
    (c) Acquisition of arms and ammunition which are peculiar to the 
military services shall be made by submission of order form to the 
Commanding General, Headquarters, U.S. Army Material Development and 
Readiness Command, 5001 Eisenhower Avenue, Alexandria, VA 22333.
[49 FR 11945, Mar. 28, 1984, as amended at 49 FR 38950, Oct. 2, 1984]



908.7112  Materials handling equipment replacement standards.

    Materials handling equipment shall be purchased for replacement 
purposes in accordance with the standards in FPMR 41 CFR 101-25.405 and 
DOE-PMR 41 CFR 109-25.4. The Heads of Contracting Activities are 
authorized to replace an item earlier than the date specified in such 
standards under unusual circumstances. A written justification shall be 
placed in the purchase file.
[49 FR 11945, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



908.7113  Calibration services.

    Orders for calibration services may be placed with the National 
Bureau of Standards, Washington, DC 20234, by either DOE acquisition 
offices or its authorized contractors. Copies of the letters authorizing 
contractors to order calibration services on behalf of DOE shall be sent 
to the Bureau of Standards, Attention: ``Administrative Services 
Division.''



908.7114  Wiretapping and eavesdropping equipment.

    Acquisition by DOE offices and contractors of devices primarily 
designed to be used surreptitiously to overhear or record conversations 
is prohibited.



908.7115  Forms.

    (a) DOE forms shall be obtained by DOE offices in accordance with 
DOE Order 1322.2, (See current version.). Cost-type contractors shall 
obtain DOE forms through the DOE contracting officer.
    (b) Standard, optional, and certain other agency forms as listed in 
the GSA Supply Catalog will be obtained by DOE offices in accordance 
with FPMR 41 CFR 101-26.302.
    (c) Marginally punched continuous forms shall be obtained in 
accordance with FPMR 41 CFR 101-26.703.
[49 FR 11945, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



908.7116  Electronic data processing tape.

    (a) Acquisitions of electronic data processing tape by DOE offices 
shall be in accordance with FPMR 41 CFR 101-26.508.
    (b) Acquisitions of electronic data processing tape by authorized 
contractors shall be in accordance with FPMR 41 CFR 101-26.508-1. 
However, if adequate justification exists, the Heads of Contracting 
Activities may authorize contractors to obtain their tape from other 
sources. When such an authorization is granted, a copy of the 
authorization and justification shall be retained in the contract file.
[49 FR 11945, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



908.7117  Tabulating machine cards.

    DOE offices shall acquire tabulating machine cards in accordance 
with FPMR 41 CFR 101-26.509.



908.7118  Rental of post office boxes.

    DOE offices and authorized contractors may rent post office boxes on 
an annual basis, or for shorter periods by

[[Page 280]]

quarters, where necessary. Payments for annual rentals are to be made in 
advance at the beginning of the fiscal year, and for periods of less 
than a year, either in advance for the whole period or at the beginning 
of each quarter in which the box is to be used.



908.7119-908.7120  [Reserved]



908.7121  Special materials.

    This section covers the purchase of materials peculiar to the DOE 
program. While purchases of these materials are unclassified, the 
specific quantities, destination or use may be classified. See 
appropriate sections of the Classification Guide. Contracting activities 
shall require authorized contractors to obtain the special materials 
identified in the following subsections in accordance with the 
procedures stated therein.
    (a) Heavy water. The Senior Program Official or designee controls 
the acquisition and production of heavy water for a given program. 
Request for orders shall be placed directly with the cognizant Senior 
Program Official or designee.
    (b) Precious metals. The DOE Oak Ridge Operations Office is 
responsible for maintaining the DOE supply of precious metals. These 
metals are platinum, palladium, iridium, osmium, rhodium, ruthenium, 
gold and silver. The DOE Oak Ridge Operations Office has assigned 
management of these metals to Martin Marietta Energy Systems, Inc., 
MS8207, P.O. Box 2009, Oak Ridge, TN 37831. DOE offices and authorized 
contractors shall coordinate with the operating contractor regarding the 
availability of the above metals prior to the purchase of these metals 
on the open market.
    (c) Lithium. Lithium is available at no cost other than normal 
packing, handling, and shipping charges from Oak Ridge. The excess 
quantities at Oak Ridge are to be considered as the first source of 
supply prior to procurement of lithium compounds from any other source.
[54 FR 27646, June 30, 1989, as amended at 59 FR 9105, Feb. 25, 1994; 62 
FR 2312, Jan. 16, 1997]



PART 909--CONTRACTOR QUALIFICATIONS--Table of Contents




           Subpart 909.1--Responsible Prospective Contractors

Sec.
909.104-1  General Standards.

         Subpart 909.4--Debarment, Suspension, and Ineligibility

909.400  Scope of subpart.
909.401  Applicability.
909.403  Definitions.
909.405  Effect of listing.
909.406  Debarment.
909.406-2  Causes for debarment.
909.406-3  Procedures.
909.406-6  Requests for reconsideration of debarment.
909.407-2  Causes for suspension.
909.407-3  Procedures.

   Subpart 909.5--Organizational and Consultant Conflicts of Interest

909.503  Waiver.
909.504  Contracting Officer's Responsibility. (DOE coverage-paragraphs 
          (d) and (e)).
909.507  Solicitation provisions and contract clause. (DOE coverage-
          paragraph (e)).
909.507-1  Solicitation provisions.
909.507-2  Contract Clause.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11949, Mar. 28, 1984, unless otherwise noted.



           Subpart 909.1--Responsible Prospective Contractors



909.104-1  General Standards.

    (h) For solicitations for contract work subject to the provisions of 
10 CFR part 707, Workplace Substance Abuse Programs at DOE sites, the 
prospective contractor must agree, in accordance with 48 CFR 970.5204-
57, Agreement Regarding Workplace Substance Abuse Programs at DOE Sites, 
to provide the contracting officer with its written workplace substance 
abuse program in order to be determined responsible and, thus, eligible 
to receive the contract award.
[57 FR 32675, July 22, 1992, as amended at 62 FR 42074, Aug. 5, 1997]

[[Page 281]]



         Subpart 909.4--Debarment, Suspension, and Ineligibility

    Source:  61 FR 39857, July 31, 1996, unless otherwise noted.



909.400  Scope of subpart.

    This subpart--
    (a) Prescribes policies and procedures governing the debarment and 
suspension of organizations and individuals from participating in 
Department of Energy (DOE) contracts, procurement sales contracts, and 
real property purchase agreements, and from participating in DOE 
approved subcontracts and subagreements.
    (b) Sets forth the causes, procedures, and requirements for 
determining the scope, duration, and effect of DOE debarment and 
suspension actions; and
    (c) Implements and supplements FAR subpart 9.4 with respect to the 
exclusion of organizations and individuals from procurement contracting 
and Government approved subcontracting.



909.401  Applicability.

    The provisions of this subpart apply to all procurement debarment 
and suspension actions initiated by DOE on or after the effective date 
of this subpart. Nonprocurement debarment and suspension rules are 
codified in 10 CFR part 1036.



909.403  Definitions.

    In addition to the definitions set forth at FAR 9.403, the following 
definitions apply to this subpart:
    Debarring Official. The DOE Debarring Official is the Deputy 
Assistant Secretary for Procurement and Assistance Management, or 
designee.
    DOE means the Department of Energy, including the Federal Energy 
Regulatory Commission.
    Suspending Official. The DOE Suspending Official is the Deputy 
Assistant Secretary for Procurement and Assistance Management, or 
designee.



909.405  Effect of listing. (DOE coverage--paragraph (e), (f), (g) and (h))

    (e) The Department of Energy may not solicit offers from, award 
contracts to or consent to subcontract with contractors debarred, 
suspended or proposed for debarment unless the Deputy Assistant 
Secretary for Procurement and Assistance Management makes a written 
determination justifying that there is a compelling reason for such 
action in accordance with FAR 9.405(a).
    (f) DOE may disapprove or not consent to the selection (by a 
contractor) of an individual to serve as a principal investigator, as a 
project manager, in a position of responsibility for the administration 
of Federal funds, or in another key personnel position, if the 
individual is on the GSA List.
    (g) DOE shall not conduct business with an agent or representative 
of a contractor if the agent's or representative's name appears on the 
GSA List.
    (h) DOE shall review the GSA List before conducting a preaward 
survey or soliciting proposals, awarding contracts, renewing or 
otherwise extending the duration of existing contracts, or approving or 
consenting to the award, extension, or renewal of subcontracts.
[61 FR 39857, July 31, 1996; 61 FR 41684, Aug. 9, 1996]



909.406  Debarment.



909.406-2  Causes for debarment. (DOE coverage--paragraphs (c) and (d))

    (c) The Debarring Official may debar a contractor for any other 
cause of so serious or compelling a nature that it affects the present 
responsibility of a DOE contractor. Such cause may include but is not 
limited to:
    (1) Commission of fraud or a criminal offense in connection with 
obtaining, attempting to obtain, or performing a private contract or 
subcontract; and
    (2) Inexcusable, prolonged, or repeated failure to pay a debt 
(including disallowed costs and overpayments) owed to DOE, provided the 
contractor has been notified of the determination of indebtedness, and 
further provided that the time for initiating any administrative or 
legal action to oppose or appeal the determination of indebtedness has 
expired or that such action, if initiated, has been concluded.
    (d) The Debarring Official may debar a contractor:
    (1) On the basis that an individual or organization is an affiliate 
of a

[[Page 282]]

debarred contractor, subject to the requirements of FAR 9.406-1(b) and 
9.406-3(c);
    (2) For failure to observe the material provisions of a voluntary 
exclusion (see 10 CFR 1036.315 for discussion of voluntary exclusion).



909.406-3  Procedures. (DOE coverage--paragraphs (a), (b) and (d))

    (a) Investigation and referral. (1) Offices responsible for the 
award and administration of contracts are responsible for reporting to 
both the Deputy Assistant Secretary for Procurement and Assistance 
Management and the DOE Inspector General information about possible 
fraud, waste, abuse, or other wrongdoing which may constitute or 
contribute to a cause(s) for debarment under this subpart. Circumstances 
that involve possible criminal or fraudulent activities must be reported 
to the Office of the Inspector General in accordance with 10 CFR part 
1010, Conduct of Employees, Sec. 1010.217(b), Cooperation with the 
Inspector General.
    (2) At a minimum, referrals for consideration of debarment action 
should be in writing and should include the following information:
    (i) The recommendation and rationale for the referral;
    (ii) A statement of facts;
    (iii) Copies of documentary evidence and a list of all witnesses, 
including addresses and telephone numbers, together with a statement 
concerning their availability to appear at a fact-finding proceeding and 
the subject matter of their testimony;
    (iv) A list of parties including the contractor, principals, and 
affiliates (including last known home and business addresses, zip codes 
and DUNS Number);
    (v) DOE's acquisition history with the contractor, including recent 
experience under contracts and copies of pertinent contracts;
    (vi) A list of any known active or potential criminal 
investigations, criminal or civil proceedings, or administrative claims 
before the Board of Contract Appeals; and
    (vii) A statement regarding the impact of the debarment action on 
DOE programs. This statement is not required for referrals by the 
Inspector General.
    (3) Referrals may be returned to the originator for further 
information or development.
    (b) Decisionmaking process. Contractors proposed for debarment shall 
be afforded an opportunity to submit information and argument in 
opposition to the proposed debarment.
    (1) In actions based upon a conviction or civil judgment, or in 
which there is no genuine dispute over material facts, the Debarring 
Official shall make a decision on the basis of all the information in 
the administrative record, including any submissions made by the 
contractor. If the respondent fails to submit a timely written response 
to a notice of proposed debarment, the Debarring Official shall notify 
the respondent in accordance with FAR 9.406-3(e) that the contractor is 
debarred.
    (2) In actions not based upon a conviction or civil judgment, the 
contractor may request a fact-finding hearing to resolve a genuine 
dispute of material fact. In its request, the contractor must identify 
the material facts in dispute and the basis for disputing the facts. If 
the Debarring Official determines that there is a genuine dispute of 
material fact, the Debarring Official shall refer the matter to the 
Energy Board of Contract Appeals for a fact-finding conference.
    (3) Meeting. Upon receipt of a timely request therefor from a 
contractor proposed for debarment, the Debarring Official shall schedule 
a meeting between the Debarring Official and the respondent, to be held 
no later than 30 days from the date the request is received. The 
Debarring Official may postpone the date of the meeting if the 
respondent requests a postponement in writing. At the meeting, the 
respondent, appearing personally or through an attorney or other 
authorized representative, may present and explain evidence that causes 
for debarment do not exist, evidence of any mitigating factors, and 
arguments concerning the imposition, scope, or duration of a proposed 
debarment or debarment.
    (4) Fact-finding conference. The purpose of a fact-finding 
conference under this section is to provide the respondent an 
opportunity to dispute material

[[Page 283]]

facts through the submission of oral and written evidence; resolve facts 
in dispute; and provide the Debarring Official with findings of fact 
based, as applicable, on adequate evidence or on a preponderance of the 
evidence. The fact-finding conference shall be conducted in accordance 
with rules consistent with FAR 9.406-3(b) promulgated by the Energy 
Board of Contract Appeals. The Energy Board of Contract Appeals will 
notify the affected parties of the schedule for the hearing. The Energy 
Board of Contract Appeals shall deliver written findings of fact to the 
Debarring Official (together with a transcription of the proceeding, if 
made) within a certain time period after the hearing record closes, as 
specified in the Energy Board of Contract Appeals Rules. The findings 
shall resolve any disputes over material facts based upon a 
preponderance of the evidence, if the case involves a proposal to debar, 
or on adequate evidence, if the case involves a suspension. Since 
convictions or civil judgments generally establish the cause for 
debarment by a preponderance of the evidence, there usually is no 
genuine dispute over a material fact that would warrant a fact-finding 
conference for those proposed debarments based on convictions or civil 
judgments.
    (d) Debarring Official's decision. (4) The Debarring Official's 
final decision shall be based on the administrative record. In those 
actions where additional proceedings are necessary as to disputed 
material facts, written findings of fact shall be prepared and included 
in the final decision. In those cases where the contractor has requested 
and received a fact-finding conference, the written findings of fact 
shall be those findings prepared by the Energy Board of Contract 
Appeals. Findings of fact shall be final and conclusive unless within 15 
days of receipt of the findings, the Department or the respondent 
requests reconsideration, as provided in the Board's Rules, or unless 
set aside by a court of competent jurisdiction. The Energy Board of 
Contract Appeals shall be provided a copy of the Debarring Official's 
final decision.



909.406-6  Requests for reconsideration of debarment.

    (a) At any time during a period of debarment, a respondent may 
submit to the Debarring or Suspending Official a written request for 
reconsideration of the scope, duration, or effects of the suspension/
debarment action because of new information or changed circumstances, as 
discussed at FAR 9.406-4(c).
    (b) In reviewing a request for reconsideration, the Debarring or 
Suspending Official may, in his or her discretion, utilize any of the 
procedures (meeting and fact-finding) set forth in 48 CFR (DEAR) 
909.406-3 and 909.407-3. The Debarring or Suspending Official's final 
disposition of the reconsideration request shall be in writing and shall 
set forth the reasons why the request has been granted or denied. A 
notice transmitting a copy of the disposition of the request for 
reconsideration shall be sent to the respondent and, if a fact-finding 
conference under 48 CFR (DEAR) 909.406-3(b)(4) is pending (as in the 
case of a request for reconsideration of a suspension, where the 
proposed debarment is the subject of a fact-finding conference), a copy 
of the disposition shall be transmitted to the Energy Board of Contract 
Appeals.



909.407-2  Causes for suspension. (DOE coverage--paragraph (d))

    (d) The Suspending Official may suspend an organization or 
individual:
    (1) Indicted for or suspected, upon adequate evidence, of the causes 
described in 48 CFR (DEAR) 909.406-2(c)(1).
    (2) On the basis of the causes set forth in 48 CFR (DEAR) 909.406-
2(d)(2).
    (3) On the basis that an organization or individual is an affiliate 
of a suspended or debarred contractor.



909.407-3  Procedures. (DOE coverage--paragraphs (b) and (e))

    (b) Decisionmaking process.
    (1) In actions based on an indictment, the Suspending Official shall 
make a decision based upon the administrative record, which shall 
include submissions made by the contractor in accordance with 48 CFR 
(DEAR) 909.406-3(b)(1) and 909.406-3(b)(3).

[[Page 284]]

    (2) For actions not based on an indictment, the procedures in 48 CFR 
(DEAR) 909.406-3(b)(2) and FAR 9.407-3(b)(2) apply.
    (3) Coordination with Department of Justice. Whenever a meeting or 
fact-finding conference is requested, the Suspending Official's legal 
representative shall obtain the advice of appropriate Department of 
Justice officials concerning the impact disclosure of evidence at the 
meeting or fact-finding conference could have on any pending civil or 
criminal investigation or legal proceeding. If such Department of 
Justice official requests in writing that evidence needed to establish 
the existence of a cause for suspension not be disclosed to the 
respondent, the Suspending Official shall:
    (i) Decline to rely on such evidence and withdraw (without 
prejudice) the suspension or proposed debarment until such time as 
disclosure of the evidence is authorized; or
    (ii) Deny the request for a meeting or fact-finding and base the 
suspension decision solely upon the information in the administrative 
record, including any submission made by the respondent.
    (e) Notice of suspending official's decision. In actions in which 
additional proceedings have been held, following such proceedings, the 
Suspending Official shall notify respondent, as applicable, in 
accordance with paragraphs (e)(1) or (e)(2) of this section.
    (1) Upon deciding to sustain a suspension, the Suspending Official 
shall promptly send each affected respondent a notice containing the 
following information:
    (i) A reference to the notice of suspension, the meeting and the 
fact-finding conference;
    (ii) The Suspending Official's findings of fact and conclusions of 
law;
    (iii) The reasons for sustaining a suspension;
    (iv) A reference to the Suspending Official's waiver authority under 
48 CFR (DEAR) 909.405;
    (v) A statement that the suspension is effective throughout the 
Executive Branch as provided in FAR 9.407-1(d);
    (vi) Modifications, if any, of the initial terms of the suspension;
    (vii) A statement that a copy of the suspension notice was sent to 
GSA and that the respondent's name and address will be added to the GSA 
List; and
    (viii) If less than an entire organization is suspended, 
specification of the organizational element(s) or individual(s) included 
within the scope of the suspension.
    (2) If the Suspending Official decides to terminate a suspension, 
the Suspending Official shall promptly send, by certified mail, return 
receipt requested, each affected respondent a copy of the final decision 
required under this section.
[61 FR 39857, July 31, 1996; 61 FR 41684, Aug. 9, 1996]



   Subpart 909.5--Organizational and Consultant Conflicts of Interest

    Source: 62 FR 40751, July 30, 1997, unless otherwise noted.



909.503  Waiver.

    Heads of Contracting Activities are delegated the authorities in 48 
CFR (FAR) 9.503 regarding the waiver of OCI requirements.



909.504  Contracting Officer's Responsibility. (DOE coverage-paragraphs (d) and (e)).

    (d) The contracting officer shall evaluate the statement by the 
apparent successful offeror or, where individual contracts are 
negotiated with all firms in the competitive range, all such firms for 
interests relating to a potential organizational conflict of interest in 
the performance of the proposed contract. Using that information and any 
other credible information, the contracting officer shall make written 
determination of whether those interests create an actual or significant 
potential organizational conflict of interest and identify any actions 
that may be taken to avoid, neutralize, or mitigate such conflict. In 
fulfilling their responsibilities for identifying and resolving 
potential conflicts, contracting officers should avoid creating 
unnecessary delays, burdensome information requirements, and excessive 
documentation.

[[Page 285]]

    (e) The contracting officer shall award the contract to the apparent 
successful offeror unless a conflict of interest is determined to exist 
that cannot be avoided, neutralized, or mitigated. Before determining to 
withold award based on organizational conflict of interest 
considerations, the contracting officer shall notify the offeror, 
provide the reasons therefor, and allow the offeror a reasonable 
opportunity to respond. If the conflict of interest cannot be avoided, 
neutralized, or mitigated to the contracting officer's satisfaction, the 
contracting officer may disqualify the offeror from award and undertake 
the disclosure, evaluation, and determination process with the firm next 
in line for award. If the contracting officer finds that it is in the 
best interest of the United States to award the contract notwithstanding 
a conflict of interest, a request for waiver shall be submitted in 
accordance with 48 CFR 909.503. The waiver request and decisions shall 
be included in the contract file.



909.507  Solicitation provisions and contract clause.



909.507-1  Solicitation provisions. (DOE coverage-paragraph (e)).

    (e) The contracting officer shall insert the provision at 48 CFR 
952.209-8, Organizational Conflicts of Interest Disclosure-Advisory and 
Assistance Services, in solicitations for advisory and assistance 
services expected to exceed the simplified acquisition threshold. In 
individual procurements, the Head of the Contracting Activity may 
increase the period subject to disclosure in 952.209-8 (c)(1) up to 36 
months.



909.507-2  Contract Clause.

    (a)(1) The contracting officer shall insert the clause at 48 CFR 
952.209-72, Organizational Conflicts of Interest, in each solicitation 
and contract for advisory and assistance services expected to exceed the 
simplified acquisition threshold.
    (2) Contracting officers may make appropriate modifications where 
necessary to address the potential for organizational conflicts of 
interest in individual contracts. Contracting officers shall determine 
the appropriate term of the bar of paragraph (b)(1)(i) of the clause at 
48 CFR 952.209-72 and enter that term in the blank provided. In the 
usual case of a contract for advisory and assistance services a period 
of three, four, or five years is appropriate; however, in individual 
cases the contracting officer may insert a term of greater or lesser 
duration.
    (3) The contracting officer shall include Alternate I with the 
clause in instances in which a meaningful amount of subcontracting for 
advisory and assistance services is expected.
    (b) Contracts, which are not subject to part 970 but provide for the 
operation of a DOE site or facility or environmental remediation of a 
specific DOE site or sites, shall contain the organizational conflict of 
interest clause at 48 CFR 952.209-72. The organizational conflicts of 
interest clause in such contracts shall include Alternate I to that 
clause.



PART 911--DESCRIBING AGENCY NEEDS--Table of Contents




                Subpart 911.6--Priorities and Allocations

Sec.
911.600  Scope of subpart.
911.602  General.
911.604  Solicitation provision and contract clause.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).



                Subpart 911.6--Priorities and Allocations



911.600  Scope of subpart.

    This subpart implements and supplements FAR Subpart 11.6, Priorities 
and Allocations, and implements the regulations and procedures of the 
Defense Priorities and Allocations System (DPAS) in solicitations and 
contracts in support of authorized national defense programs and those 
energy programs which maximize domestic energy supplies. (See 15 CFR 
part 700).
[52 FR 38422, Oct. 16, 1987, as amended at 59 FR 9105, Feb. 25, 1994. 
Redesignated and amended at 61 FR 21976, May 13, 1996; 61 FR 30823, June 
18, 1996]

[[Page 286]]



911.602  General.

    (d) Programs which maximize domestic energy supplies are eligible 
for priorities and allocations support depending on an executive 
decision made on a case-by-case basis. Eligibility is pursuant to 
section 104(a) of the Energy Conservation and Policy Act, Pub. L. 94-
163, which added a new section 101(c) to the Defense Production Act. 
Guidance is provided by 10 CFR part 216 and Department of Energy 
publication DOE/MA-0192, ``Priorities and Allocations Support for 
Energy: Keeping Energy Programs on Schedule,'' dated August 1985. Rated 
orders placed in support of authorized energy programs are equivalent to 
orders placed in support of authorized defense programs under the DPAS 
and receive the same preferential treatment throughout the industrial 
supply chain.
    (e) The Heads of Contracting Activities shall ensure that members of 
their staffs and contractors under their jurisdiction are advised of the 
provisions of the DPAS regulation and that the related procedures are 
followed to ensure adherence to the regulation throughout the industrial 
supply chain. Under DPAS, it is mandatory that the priority rating be 
extended through the industrial chain from supplier to supplier.
[52 FR 38422, Oct. 16, 1987, as amended at 59 FR 9105, Feb. 25, 1994. 
Redesignated at 61 FR 21976, May 13, 1996]



911.604  Solicitation provision and contract clause.

    (a) The contracting officer shall insert the provision at 952.211-
70, Priorities and Allocations (Atomic Energy), in solicitations that 
will result in the placement of rated orders for authorized DOE atomic 
energy programs.
    (b) The contracting officer shall insert the clause at 952.211-71, 
Priorities and Allocations (Atomic Energy) in contracts that are placed 
in support of authorized DOE atomic energy programs.
    (c) The use of the provisions at 952.211-70 and the clause at 
952.211-71 is optional for industrial delivery orders of $5,000 or less.
    (d) The contracting officer shall insert the provision at 952.211-70 
(Alternate I), Priorities and Allocations (Domestic Energy Supplies), in 
solicitations that may result in the placement of rated orders for 
authorized energy programs.
    (e) The contracting officer shall insert the clause at 952.211-71 
(Alternate I), Priorities and Allocations (Domestic Energy Supplies), if 
it is believed the contract involves a program the purpose of which is 
to maximize domestic energy supplies.
[52 FR 38422, Oct. 16, 1987, as amended at 59 FR 9105, Feb. 25, 1994. 
Redesignated and amended at 61 FR 21976, May 13, 1996]



PART 912 [RESERVED]




[[Page 287]]



          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES





PART 913--SIMPLIFIED ACQUISITION PROCEDURES--Table of Contents




                  Subpart 913.3--Fast Payment Procedure

Sec.
913.301  General.

                      Subpart 913.4--Imprest Funds

913.403  Agency responsibilities.

                     Subpart 913.5--Purchase Orders

913.505-1  Optional Form (OF) 347, Order for Supplies or Services, and 
          Optional Form 348, Order for Supplies or Services Schedule-
          Continuation or DOE F 4250.3, Order for Supplies or Services.
913.507  Clauses.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).



                  Subpart 913.3--Fast Payment Procedure



913.301  General.

    The fast payment procedure delineated in FAR Subpart 13.3 is not to 
be utilized by DOE.
[49 FR 11954, Mar. 28, 1984]



                      Subpart 913.4--Imprest Funds



913.403  Agency responsibilities.

    (d) If imprest funds are to be used, the HCA shall issue detailed 
procedures for the control of such funds.
[49 FR 11954, Mar. 28, 1984]



                     Subpart 913.5--Purchase Orders



913.505-1  Optional Form (OF) 347, Order for Supplies or Services, and Optional Form 348, Order for Supplies or Services Schedule-Continuation or DOE F 4250.3, 
          Order for Supplies or Services.

    (a)(2) Optional Forms 347 and 348, or DOE F 4250.3 may be used for 
purchase orders using simplified acquisition procedures. These forms 
shall not be used as the contractor's invoice. Standard Form 1449 shall 
be used for acquisitions of commercial items.
    (b)(2) An addendum of applicable clauses is provided to contracting 
activities from the Office of Policy, within the Headquarters 
procurement organization, shall be used with each Optional Form 347 or 
Standard Form 1449.
[52 FR 38423, Oct. 16, 1987, as amended at 58 FR 36365, July 7, 1993; 59 
FR 9105, Feb. 25, 1994; 61 FR 21976, May 13, 1996]



913.507  Clauses.

    The contracting officer shall insert the clause at 970.5204-59, 
Whistleblower Protection for Contractor Employees, in purchase orders 
involving work to be performed on-site at a DOE- owned or leased 
facility, after adding to the end of paragraph (a) of that clause, the 
phrase ``with respect to work performed on-site at a DOE-owned or -
leased facility, as provided for at 10 CFR part 708.'' The term ``work 
performed on-site'' is defined at 970.2274(b).
[57 FR 57639, Dec. 4, 1992; 58 FR 39679, July 26, 1993]



PART 914--SEALED BIDDING--Table of Contents




          Subpart 914.4--Opening of Bids and Award of Contract

Sec.
914.404-1  Cancellation of invitations after opening.
914.406  Mistakes in bids.
914.406-3  Other mistakes disclosed before award.
914.406-4  Mistakes after award.
914.408-2  Award of classified contracts.

                 Subpart 914.5--Two-Step Sealed Bidding

914.502  Conditions for use.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11954, Mar. 28, 1984, unless otherwise noted.



          Subpart 914.4--Opening of Bids and Award of Contract



914.404-1  Cancellation of invitations after opening.

    (c) The Procurement Executive has been delegated authority to make 
the

[[Page 288]]

determination under FAR 14.404-1(c) and (e) and has redelegated this 
authority to the Heads of Contracting Activities without power of 
redelegation.
[50 FR 12184, Mar. 27, 1985]



914.406  Mistakes in bids.



914.406-3  Other mistakes disclosed before award.

    (e) Pursuant to FAR 14.406-3(e), the Procurement Executive, has been 
delegated authority by the Secretary to make the determinations under 
FAR 14.406-3. In the case of mistakes in bids alleged after opening of 
bids and before award, the Procurement Executive has redelegated this 
authority to the Heads of Contracting Activities without power of 
redelegation and to make administrative determinations regarding 
withdrawal of bids as provided for in FAR 14.406-3, providing that each 
such determination shall be approved by Legal Counsel.
[49 FR 11954, Mar. 28, 1984, as amended at 56 FR 41964, Aug. 26, 1991; 
59 FR 9105, Feb. 25, 1994]



914.406-4  Mistakes after award.

    The Procurement Executive has been delegated authority to make the 
determinations under FAR 14.406-4. Mistakes in bids after award, 
together with the data set forth in FAR 14.406-4(e), shall be submitted 
to the Procurement Executive for decision.



914.408-2  Award of classified contracts.

    DOE regulations regarding the safeguarding of restricted data and 
procedures for its destruction are contained at 10 CFR part 1016.
[49 FR 11954, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



                 Subpart 914.5--Two-Step Sealed Bidding



914.502  Conditions for use.

    (c) Use of the two-step sealed bidding method shall be approved by 
the Head of the Contracting Activity. The contracting officer shall 
submit a written request for approval justifying its use in accordance 
with FAR 14.502.
[50 FR 12184, Mar. 27, 1985]



PART 915--CONTRACTING BY NEGOTIATION--Table of Contents




   Subpart 915.4--Solicitation and Receipt of Proposals and Quotations

Sec.
915.401  Applicability.
915.405-1  General.
915.413  Disclosure and use of information before award.
915.413-2  Alternate II.

                  Subpart 915.5--Unsolicited Proposals

915.502  Policy.
915.503  General.
915.505  Content of unsolicited proposals.
915.506  Agency procedures.
915.507  Contracting methods.

                    Subpart 915.8--Price Negotiation

915.804-3  Exemptions from or waiver of submission of certified cost or 
          pricing data.
915.804-6  Procedural requirements.
915.805-5  Field pricing support.
915.805-70  Audit as an aid in proposal analysis.

                          Subpart 915.9--Profit

915.903  Contracting officer responsibilities.
915.905  Profit-analysis factors.
915.970  DOE structured profit and fee system.
915.970-1  General.
915.970-2  Weighted guidelines system.
915.970-3  Documentation.
915.970-4  Exceptions.
915.970-5  Special considerations--contracts with nonprofit 
          organizations (other than educational institutions).
915.970-6  Contracts with educational institutions.
915.970-7  Alternative techniques.
915.970-8  Weighted guidelines application considerations.
915.971  Profit and fee-system for construction and construction 
          management contracts.
915.971-1  General.
915.971-2  Limitations.
915.971-3  Factors for determining fees.
915.971-4  Considerations affecting fee amounts.
915.971-5  Fee schedules.
915.971-6  Fee base.
915.972  Special considerations for cost-plus-award-fee contracts.

[[Page 289]]

Subpart 915.10--Preaward, Award, and Postaward Notifications, Protests, 
                              and Mistakes

915.1003  Debriefing of unsuccessful offerors.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11955, Mar. 28, 1984, unless otherwise noted.



   Subpart 915.4--Solicitation and Receipt of Proposals and Quotations



915.401  Applicability.

    In addition to the exclusions included at FAR 15.401, FAR 15.4 is 
not applicable to Program Opportunity Notices (See 917.72), or Program 
Research and Development Announcements (See 917.73).
[49 FR 11955, Mar. 28, 1984, as amended at 62 FR 2312, Jan. 16, 1997]



915.405-1  General.

    Approval for the use of solicitations for information or planning 
purposes shall be obtained from the Head of the Contracting Activity.
[49 FR 11955, Mar. 28, 1984, as amended at 56 FR 41964, Aug. 26, 1991]



915.413  Disclosure and use of information before award.



915.413-2  Alternate II.

    The procedures discussed at FAR 15.413-2 may be used if approved at 
a level above the contracting officer. See also 927.70.



                  Subpart 915.5--Unsolicited Proposals

    Source:  61 FR 41705, Aug. 9, 1996, unless otherwise noted.



915.502  Policy.

    (a) Present and future needs demand the involvement of all resources 
in exploring alternative energy sources and technologies. To achieve 
this objective, it is DOE policy to encourage external sources of unique 
and innovative methods, approaches, and ideas by stressing submission of 
unsolicited proposals for government support. In furtherance of this 
policy and to ensure the integrity of the acquisition process through 
application of reasonable controls, the DOE:
    (1) Disseminates information on areas of broad technical concern 
whose solutions are considered relevant to the accomplishment of DOE's 
assigned mission areas;
    (2) Encourages potential proposers to consult with program personnel 
before expending resources in the development of written unsolicited 
proposals;
    (3) Endeavors to distribute unsolicited proposals to all interested 
organizations within DOE;
    (4) Processes unsolicited proposals in an expeditious manner and, 
where practicable, keeps proposers advised as discrete decisions are 
made;
    (5) Assures that each proposal is evaluated in a fair and objective 
manner; and,
    (6) Assures that each proposal will be used only for its intended 
purpose and the information, subject to applicable laws and regulations, 
contained therein will not be divulged without prior permission of the 
proposer.
    (b) Extensions of contract work resulting from unsolicited proposals 
shall be processed in accordance with the procedures at 48 CFR 943.170.



915.503  General. (DOE coverage--paragraph (f))

    (f) Unsolicited proposals for the performance of support services 
are, except as discussed in this paragraph, unacceptable as the 
performance of such services is unlikely to necessitate innovative and 
unique concepts. There may be rare instances in which an unsolicited 
proposal offers an innovative and unique approach to the accomplishment 
of a support service. If such a proposal offers a previously unknown or 
an alternative approach to generally recognized techniques for the 
accomplishment of a specific service(s) and such approach will provide 
significantly greater economy or enhanced quality, it may be considered 
for acceptance. Such acceptance shall, however, require approval of the 
acquisition of support services in accordance with applicable DOE 
Directives and be processed as a deviation to the prohibition in this 
paragraph.

[[Page 290]]



915.505  Content of unsolicited proposals. (DOE coverage--paragraph (b))

    (b)(5) Unsolicited proposals for nonnuclear energy demonstration 
activities not covered by existing formal competitive solicitations or 
program opportunity notices may include a request for federal assistance 
or participation, and shall be subject to the cost sharing provisions of 
48 CFR 917.70.



915.506  Agency procedures. (DOE coverage--paragraph (b))

    (b) Unless otherwise specified in a notice of program interest, all 
unsolicited proposals should be submitted to the Unsolicited Proposal 
Coordinator, Office of Procurement and Assistance, Washington, DC 20585. 
If the proposer has ascertained the cognizant program office through 
preliminary contacts with program staff, the proposal may be submitted 
directly to that office. In such instances, the proposer should 
separately send a copy of the proposal cover letter to the unsolicited 
proposal coordinator to assure that the proposal is logged in the 
Department's automated tracking system for unsolicited proposals.



915.507  Contracting methods. (DOE coverage--paragraph (d))

    (d) DOE's cost participation policy, at 48 CFR 917.70, shall be 
followed in determining the extent to which the DOE will participate in 
the cost for the proposed effort.



                    Subpart 915.8--Price Negotiation



915.804-3  Exemptions from or waiver of submission of certified cost or pricing data.

    (b)(2)(iii) The Heads of Contracting Activities, for contracts 
estimated to be within the limits of their delegated authority, may 
approve the finding required by FAR 15.804-3(b)(2)(iii) that the lowest 
price received is unreasonable.
    (c)(8) The Heads of Contracting Activities, for contracts estimated 
to be within the limits of their delegated authority, may approve the 
finding required by FAR 15.804-3(c)(8) that the price is unreasonable 
even though it is a catalog or market price.
    (g) The Heads of Contracting Activities, for contracts estimated to 
be within the limits of their delegated authority, may, without power of 
redelegation, authorize individual or class exemptions for exceptional 
cases in accordance with FAR 15.804-3(g).
    (i) The Heads of Contracting Activities, for contracts estimated to 
be within the limits of their delegated authority, may, without power of 
redelegation, waive the requirements for cost or pricing data under the 
circumstances set forth in FAR 15.804-3(i) provided that any such 
waivers are promptly reported to the Procurement Executive.
[49 FR 11955, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



915.804-6  Procedural requirements.

    (e) The Heads of Contracting Activities, for contracts estimated to 
be within the limits of their delegated authority, may, without power of 
redelegation, waive the requirements for cost or pricing data under the 
circumstances set forth in FAR 15.804-6(e) provided that any such 
waivers are promptly reported to the Procurement Executive.
    (i) The Heads of Contracting Activities, for contracts estimated to 
be within the limits of their delegated authority, may, without power of 
redelegation, waive the requirements for subcontractor cost or pricing 
data under the circumstances set forth in FAR 15.804-6(i), provided that 
any such waivers are promptly reported to the Procurement Executive.
[49 FR 11955, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



915.805-5  Field pricing support.

    (a)(1) Field pricing reports as prescribed in FAR 15.805-5(a)(1) are 
not required for the negotiation of DOE contract prices or modifications 
thereof. The term ``field pricing report'' refers to the Department of 
Defense (DOD) system for obtaining a price and/or cost analysis report 
from a cognizant DOD field level contract management office wherein 
requests for the review of a proposal submitted by an offeror are 
initiated and the recommendations made by the various specialists of the

[[Page 291]]

management office are consolidated into a single report that is 
forwarded to the office making the contract award for use in conducting 
negotiations. In the DOE, such review activities, except for reviews 
performed by professional auditors, are expected to be accomplished by 
pricing support personnel located in DOE Contracting Activities. The DOE 
contracting officer shall formally request the assistance of appropriate 
pricing support personnel, other than auditors, for the review of any 
proposal that exceeds $500,000, unless the contracting officer has 
sufficient data to determine the reasonableness of the proposed cost or 
price. Such pricing support may be requested for proposals below 
$500,000, if considered necessary for the establishment of a reasonable 
pricing arrangement. Contracting officers, however, are not precluded by 
this section from requesting pricing assistance from a cognizant DOD 
contract management office, provided an appropriate cross-servicing 
arrangement for pricing support services exists between the DOE and the 
servicing agency.
    (c)(1) When an audit is required pursuant to 915.805-70, ``Audit as 
an aid in proposal analysis,'' the request for audit shall be sent 
directly to the Federal audit office assigned cognizance of the offeror 
or prospective contractor. When the cognizant agency is other than the 
Defense Contract Audit Agency or the Department of Health and Human 
Services, and an appropriate interagency agreement has not been 
established, the need for audit assistance shall be coordinated with the 
Office of Policy, within the Headquarters procurement organization.
    (2) The request for audit shall establish the due date for receipt 
of the auditor's report and in so doing shall allow as much time as 
possible for the auditor's review.
    (e)(6) Copies of technical analysis reports prepared by DOE 
technical or other pricing support personnel shall not normally be 
provided to the auditor. The contracting officer or the supporting 
price, cost, or financial analyst at the contracting activity shall 
determine the monetary impact of the technical findings.
[49 FR 11955, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994; 60 
FR 30004, June 7, 1995]



915.805-70  Audit as an aid in proposal analysis.

    (a) When a contract price will be based on cost or pricing data (FAR 
15.804) submitted by the offerors, the DOE contracting officer or 
authorized representative shall request a review by the cognizant 
Federal audit activity prior to the negotiation of any contract or 
modification including modifications under advertised contracts in 
excess of:
    (1) $500,000 for a firm fixed-price contract or a fixed-price 
contract with economic price adjustment provisions; or
    (2) $1,000,000 for all other contract types, including initial 
prices, estimated costs of cost-reimbursement contracts, interim and 
final price redeterminations, and target and settlement of incentive 
contracts.
    (b) The requirement for auditor reviews of proposals which exceed 
the thresholds specified in paragraph (d) above may be waived at a level 
above the contracting officer when the reasonableness of the negotiated 
contract price can be determined from information already available. The 
contract file shall be documented to reflect the reason for any such 
waiver, provided, however, that independent Government estimates of cost 
or price shall not be used as the sole justification for any such 
waiver.
[49 FR 11955, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984; 60 FR 47308, 
Sept. 12, 1995]



                          Subpart 915.9--Profit



915.903  Contracting officer responsibilities.

    (d)(1)(ii) The statutory limitations on profit and fees as set forth 
in FAR 15.903(d)(1) (i), (ii) and (iii) shall be followed, except as 
exempted for DOE architect-engineer contracts covering Atomic Energy 
Commission (AEC) and Bonneville Power Administration (BPA) functions. 
Pursuant to section

[[Page 292]]

602(d) (13) and (20) of the Federal Property and Administration Services 
Act of 1949, as amended, those former AEC functions, as well as those of 
the BPA, now being performed by DOE are exempt from the 10 and 6 per 
centum cost and fee restrictions on contracts for architect-engineer 
services.
    (d)(2) Waivers to apply the maximum cost-plus-award-fee percentage 
in 915.972(a)(3) in those situations that shall result in potential fees 
exceeding the limitations cited in FAR 15.903(d)(1) (i), (ii), and (iii) 
shall be forwarded to the Procurement Executive.
    (f) In cases where a change or modification calls for substantially 
different work than the basic contract, the contractor's effort may be 
radically changed and a detailed analysis of the profit factors would be 
a necessity. Also, if the dollar amount of the change or contract 
modification is very significant in comparison to the contract dollar 
amount, a detailed analysis should be made.
    (g) The estimated costs on which the maximum fee is computed 
pursuant to the statutory limitations set forth in FAR 15.903(d)(1) 
shall include facilities capital cost of money when this cost is 
included in cost estimates.
[49 FR 11955, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



915.905  Profit-analysis factors.

    A profit/fee analysis technique designed for a systematic 
application of the profit factors in FAR 15.905-1 provides contracting 
officers with an approach that will ensure consistent consideration of 
the relative value of the various factors in the establishment of a 
profit objective and the conduct of negotiations for a contract award. 
It also provides a basis for documentation of this objective, including 
an explanation of any significant departure from it in reaching a final 
agreement. The contracting officer's analysis of these prescribed 
factors is based on information available prior to negotiations. Such 
information is furnished in proposals, audit data, performance reports, 
preaward surveys and the like.



915.970  DOE structured profit and fee system.

    This section implements FAR 15.902 and 15.905.



915.970-1  General.

    (a) Objective. It is the intent of DOE to remunerate contractors for 
financial and other risks which they may assume, resources they use, and 
organization, performance and management capabilities they employ. 
Profit or fee shall be negotiated for this purpose; however, when profit 
or fee is determined as a separate element of the contract price, the 
aim of negotiation should be to fit it to the acquisition, giving due 
weight to effort, risk, facilities investment, and special factors as 
set forth in this subpart.
    (b) Commercial (profit) organization. Profit or fee prenegotiation 
objectives for contracts with commercial (profit) organizations shall be 
determined as provided in this subpart.
    (c) Nonprofit organizations. It is DOE's general policy to pay fees 
in contracts with nonprofit organizations other than educational 
institutions and governmental bodies; however, it is a matter of 
negotiation whether a fee will be paid in a given case. In making this 
decision, the DOE negotiating official should consider whether the 
contractor is ordinarily paid fees for the type of work involved. The 
profit objective should be reasonable in relation to the task to be 
performed and the requirements placed on the contractor.
    (d) Educational institutions. It is DOE policy not to pay fees under 
contracts with educational institutions.
    (e) State, local and Indian tribal governments. Profit or fee shall 
not be paid under contracts with State, local, and Indian tribal 
Governments.



915.970-2  Weighted guidelines system.

    (a) To properly reflect differences among contracts and the 
circumstances relating thereto and to select an appropriate relative 
profit/fee in consideration of these differences and circumstances, 
weightings have been developed for application by the contracting 
officer to standard measurement bases representative of the prescribed 
profit factors cited in FAR 15.905 and paragraph (d) of this section.

[[Page 293]]

This is a structured system, referred to as weighted guidelines. Each 
profit factor or subfactor, or component thereof, has been assigned 
weights relative to their value to the contract's overall effort. The 
range of weights to be applied to each profit factor is also set forth 
in paragraph (d) of this section. Guidance on how to apply the weighted 
guidelines is set forth in 915.970-8.
    (b) Except as set forth in 915.970-4, the weighted guidelines shall 
be used in establishing the profit objective for negotiation of 
contracts where cost analysis is performed.
    (c) The negotiation process does not contemplate or require 
agreement on either estimated cost elements or profit elements. 
Accordingly, although the details of analysis and evaluation may be 
discussed in the fact-finding phase of the negotiation process in order 
to develop a mutual understanding of the logic of the respective 
positions, specific agreement on the exact weights of values of the 
individual profit factors is not required and need not be attempted.
    (d) The factors set forth below are to be used in determining DOE 
profit objectives. The factors and weight ranges for each factor shall 
be used in all instances where the weighted guidelines are applied.

                                                                        
------------------------------------------------------------------------
               Profit factors                  Weight ranges (percent)  
------------------------------------------------------------------------
I. Contractor Effort (Weights applied to                                
 cost):                                                                 
  A. Material acquisitions:                                             
    1. Purchased parts.....................  1 to 3.                    
    2. Subcontracted items.................  1 to 4.                    
    3. Other materials.....................  1 to 3.                    
  B. Labor skills:                                                      
    1. Technical and managerial:                                        
      a. Scientific........................  10 to 20.                  
      b. Project management/administration.  8 to 20.                   
      c. Engineering.......................  8 to 14.                   
    2. Manufacturing.......................  4 to 8.                    
    3. Support services....................  4 to 14.                   
  C. Overhead:                                                          
    1. Technical and managerial............  5 to 8.                    
    2. Manufacturing.......................  3 to 6.                    
    3. Support services....................  3 to 7.                    
  D. Other direct costs....................  3 to 8.                    
  E. G&A (General Management) expenses.....  5 to 7.                    
II. Contract Risk (type of contract--        0 to 8.                    
 weights applied to total cost of items IA                              
 thru E).                                                               
III. Capital Investment (Weights applied to  5 to 20.                   
 the net book value of allocable                                        
 facilities).                                                           
IV. Independent Research and Development:                               
  A. Investment in IR&D program (Weights     5 to 7.                    
   applied to allocable IR&D costs).                                    
  B. Developed items employed (Weights       0 to 20.                   
   applied to total of profit $ for items                               
   IA thru E).                                                          
V. Special Program Participation (Weights    -5 to +5.                  
 applied to total of Profit $ for items IA                              
 thru E).                                                               
VI. Other Considerations (Weights applied    -5 to +5.                  
 to total of Profits $ for items 1A thru E).                            
VII. Productivity/Performance (special       (N/A)                      
 computation).                                                          
------------------------------------------------------------------------



915.970-3  Documentation.

    Determination of the profit or fee objective, in accordance with 
this subpart shall be fully documented. A worksheet, DOE Form F 4220.23 
has been developed to assist the contracting officer in this effort. 
Since the profit objective is the contracting officer's pre-negotiation 
evaluation of a total profit allowance for the proposed contract, the 
amounts developed for each category of cost will probably change in the 
course of negotiation. Furthermore, the negotiated amounts will probably 
vary from the objective and from the pre-negotiation detailed 
application of the weighted guidelines technique to each element of the 
contractor's input to total performance. Since the profit objective is 
viewed as a whole rather than as its component parts, insignificant 
variations from the pre-negotiation profit objective, as a result of 
changes to the contractor's input to total performance, need not be 
documented in detail. Conversely, significant deviations from the profit 
objective necessary to reach a final agreement on profit or fee shall be 
explained in the price negotiation memorandum prepared in accordance 
with FAR 15.808.



915.970-4  Exceptions.

    (a) For contracts not expected to exceed $500,000, the weighted 
guidelines need not be used; however, the contracting officer may use 
the weighted guidelines for contracts below this amount if he or she 
elects to do so.
    (b) For the following classes of contracts, the weighted guidelines 
shall not be used:
    (1) Commercialization and demonstration type contracts;
    (2) Management and operating contracts;
    (3) Construction contracts;
    (4) Construction management contracts;

[[Page 294]]

    (5) Contracts primarily requiring delivery of material supplied by 
subcontractors;
    (6) Termination settlements; and
    (7) Contracts with educational institutions.
    (c) In addition to paragraphs (a) and (b) of this section, the 
contracting officer need not use the weighted guidelines in unusual 
pricing situations where the weighted guidelines method has been 
determined by the DOE negotiating official to be unsuitable. Such 
exceptions shall be justified in writing and shall be authorized by the 
Head of the Contracting Activity. The contract file shall include this 
documentation and any other information that may support the exception.
    (d) If the contracting officer makes a written determination that 
the pricing situation meets any of the circumstances set forth above, 
other methods for establishing the profit objective may be used. For 
contracts other than those subject to subpart 917.6, the selected method 
shall be supported in a manner similar to that used in the weighted 
guidelines (profit factor breakdown and documentation of profit 
objectives); however, investment or other factors that would not be 
applicable to the contract shall be excluded from the profit objective 
determination. It is intended that the methods will result in profit 
objectives for noncapital intensive contracts that are below those 
generally developed for capital intensive contracts.
[49 FR 11955, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



915.970-5  Special considerations--contracts with nonprofit organizations (other than educational institutions).

    (a) For purposes of identification, nonprofit organizations are 
defined as those business entities organized and operated exclusively 
for charitable, scientific, or educational purposes, of which no part of 
the net earnings inure to the benefit of any private shareholder or 
individual, of which no substantial part of the activities is attempting 
to influence legislation or participating in any political campaign on 
behalf of any candidate for public office, and which are exempt from 
Federal income taxation under section 501 of the Internal Revenue Code.
    (b) In computing the amount of profit or fee to be paid, the DOE 
negotiating official shall take into account the tax benefits received 
by a nonprofit organization. While it is difficult to establish the 
degree to which a remuneration under any given contract contributes to 
an organization's overall net profit, the DOE negotiating official 
should assume that there is an element of profit in any amount to be 
paid.
    (c) In order to assure consideration of the tax posture of nonprofit 
organizations during a profit or fee negotiation, the DOE negotiating 
official shall calculate the fee as for a contract with a commercial 
concern and then reduce it at least 25 percent. However, depending on 
the circumstances, the contracting officer may pay profit or fees 
somewhere between this amount and the appropriate profit or fee as if it 
were a commercial concern. When this is the case, the contract file 
shall be documented to specifically state the reason or reasons.
    (d) Where a contract with a nonprofit organization is for the 
operation of Government-owned facilities, the fee should be calculated 
using the procedures and schedules applicable to operating contracts as 
set forth in part 970.



915.970-6  Contracts with educational institutions.

    In certain situations the DOE may contract with a university to 
manage or operate Government-owned laboratories. These efforts are 
generally apart from, and not in conjunction with, their other 
activities, and the complexity and magnitude of the work are not 
normally found in standard university research or study contracts. Such 
operating contracts are subject to the applicable provisions set forth 
in part 970.



915.970-7  Alternative techniques.

    (a) Profit or fees to be paid on construction contracts and 
construction management contracts shall be determined in accordance with 
the applicable profit/fee technique for such contracts set forth in 
915.971.
    (b) Profit and fee to be paid on contracts under $500,000, not using 
the

[[Page 295]]

weighted guidelines, shall be judgmentally developed by the contracting 
officer by assigning individual dollar amounts to the factors 
appropriate to DOE profit considerations discussed in 915.970-2(d).
    (c) Contracts which require only delivery or furnishing of goods or 
services supplied by subcontractors shall include a fee or profit which, 
in the best judgment of the contracting officer, is appropriate. It 
would be expected that there would be a declining relationship of 
profit/fee dollars in relation to total costs. The higher the cost of 
subcontracts, for example, the lower the profit/fee ratio to these 
costs.
    (d) Profit/Fee considerations in termination settlements are often a 
question of equity. They are a matter of negotiation. They should not, 
however, exceed what would have otherwise been payable under weighted 
guidelines had the termination not occurred.



915.970-8  Weighted guidelines application considerations.

    The Department has developed internal procedures to aid the 
contracting officer in the application of weighted guidelines and to 
assure a reasonable degree of uniformity across the Department.
[61 FR 41706, Aug. 9, 1996]



915.971  Profit and fee-system for construction and construction management contracts.



915.971-1  General.

    (a) Business concerns awarded a DOE construction or construction 
management contract shall be paid a profit or fee if requested or 
solicited. The profit or fee objective for a construction or 
construction management contract shall be an amount appropriate for the 
type of effort contained therein. It is the intent of DOE to (1) reward 
contractors based on the complexity of work, (2) reward contractors who 
demonstrate and establish excellent records of performance and (3) 
reward contractors who contribute their own resources, including 
facilities and investment of capital.
    (b) Standard fees or across-the-board agreements will not be used or 
made. Profit or fee objectives are to be determined for each contract 
according to the effort or task contracted for thereunder.
    (c) Profit or fee payable on fixed-price and cost-reimbursable 
construction or construction management contracts shall be established 
in accordance with the appropriate procedures and schedules set forth in 
this subpart.



915.971-2  Limitations.

    Amounts payable under construction and construction management 
contracts shall not exceed amounts derived from the schedules 
established for this purpose. Requests to pay fees in excess of these 
levels shall be forwarded to the Procurement Executive for review and 
approval.



915.971-3  Factors for determining fees.

    (a) The profit policy stated in 915.971-1(a) reflects, in a broad 
sense, recognition that profit is compensation to contractors for the 
entrepreneurial function of organizing and managing resources (including 
capital resources), and the assumption of risk that all costs of 
performance (operating and capital) may not be reimbursable.
    (b) The best approach calls for a structure that allows judgmental 
evaluation and determination of fee dollars for prescribed factors which 
impact the need for, and the rewards associated with, fee or profit, as 
follows.
    (i) Management risk relating to performance, including the (A) 
quality and diversity of principal work tasks required to do the job, 
(B) labor intensity of the job, (C) special control problems, and (D) 
advance planning, forecasting and other such requirements;
    (ii) The presence or absence of financial risk, including the type 
and terms of the contract;
    (iii) The relative difficulty of work, including consideration of 
technical and administrative knowledge, skill, experience and clarity of 
technical specifications;
    (iv) Degree and amount of contract work required to be performed by 
and with the contractor's own resources, including the extent to which 
the contractor contributes plant, equipment, computers, or working 
capital (labor, etc.);

[[Page 296]]

    (v) Duration of project;
    (vi) Size of operation;
    (vii) Benefits which may accrue to the contractor from gaining 
experience and know-how, from establishing or enhancing a reputation, or 
from being enabled to hold or expand a staff whose loyalties are 
primarily to the contractor; and
    (viii) Other special considerations, including support of Government 
programs such as those relating to small, small disadvantaged and women-
owned small business in subcontracting, energy conservation, etc.
    (c) The total fee objective and amount for a particular negotiation 
is established by judgmental considerations of the above factors, 
assigning fee values as deemed appropriate for each factor and totaling 
the resulting amounts.
    (d) In recognition of the complexities of this process, and to 
assist in promoting a reasonable degree of consistency and uniformity in 
its application, fee schedules have been developed which set forth 
maximum fee amounts that contracting activities are allowed to negotiate 
for a particular transaction without obtaining prior approval of the 
Procurement Executive. In addition, the fee negotiation objective 
established in accordance with 915.971-3(a), (b), and (c) shall not 
exceed the applicable fee schedule amounts without prior approval of the 
Procurement Executive. To facilitate application to a contract, the fee 
amounts are related to the total cost base which is defined as total 
operating and capital costs.
[49 FR 11955, Mar. 28, 1984, as amended at 61 FR 21976, May 13, 1996]



915.971-4  Considerations affecting fee amounts.

    (a) In selecting final fee amounts for the various factors in 
915.971-3 of this section, the DOE negotiating official will have to 
make several judgments as discussed in this subsection.
    (b) Complexity of a construction project shall be considered by 
analysis of its major parts. For a project which includes items of work 
of different degrees of complexity, a single average classification 
should be considered, or the work should be divided into separate 
classifications. The following class identifications are appropriate for 
proper fee determinations.
    (1) Class A--Manufacturing plants involving continuous closed 
processes or other complicated operations requiring a high degree of 
design layout or process control; nuclear reactors; atomic particle 
accelerators; complex laboratories or industrial units especially 
designed for handling radioactive materials.
    (2) Class B--Normal manufacturing processes and assembly operations 
such as ore dressing, metal working plant and simple processing plants; 
power plants and accessory switching and transformer stations; water 
treatment plants; sewage disposal plants; hospitals; and ordinary 
laboratories.
    (3) Class C--Permanent administrative and general service buildings, 
permanent housing, roads, railroads, grading, sewers, storm drains, and 
water and power distribution systems.
    (4) Class D--Construction camps and facilities and other 
construction of a temporary nature.
    (c) Normal management elements of principal tasks relating to a 
construction contract cover several categories of tasks with differing 
rates of application throughout the construction period. The principal 
elements of management effort are outlined in this paragraph. Although 
each project has a total management value equal to 100% for all 
elements, the distribution of effort among the various elements will be 
different for each project due to differences in project character or 
size. The basic management elements and the normal range of efforts 
expected to apply for a normal sized project are as follows. When the 
normally expected effort will not be performed by a contractor, this 
fact should be considered in arriving at appropriate fee amounts.

                                                                        
------------------------------------------------------------------------
                                                          Effort range  
                  Management elements                  -----------------
                                                        Minimum  Maximum
------------------------------------------------------------------------
I. Broad project planning.-- Overall project planning                   
 and scheduling, establishment of key project                           
 organization and consultation with the A-E and DOE.                    
 Performed by highest level of contractor's officers,                   
 technical personnel and project manager..............       15       25

[[Page 297]]

                                                                        
II. Field planning.-- Mobilization and demobilization                   
 of top field organization from the contractor's                        
 existing organization and from other sources as                        
 necessary. Detailed project planning and scheduling                    
 for construction of facilities. Performed by the                       
 project manager and top field professional staff.....       18       28
III. Labor supervision.-- Direct supervision of manual                  
 employees. Performed by contractor's subprofessional                   
 staff, such as superintendents and foremen (some                       
 salaried and some hourly rate). This includes the                      
 contractor's personnel to coordinate and expedite the                  
 work of subcontractors...............................       12       16
IV. Acquisition and subcontracting.-- Acquisition of                    
 other than special equipment. Selection of                             
 subcontractors and execution and administration of                     
 subcontracts. Performed by contractor's staff under                    
 supervision and direction of elements I and II.......       12       16
V. Labor relations and recruitment (manual).--                          
 Performed by the contractor's staff under supervision                  
 and direction of elements I, II and III. This                          
 includes demobilization of work forces...............        7       11
VI. Recruitment of supervisory staff.-- Staffing                        
 required to supplement the organization under                          
 elements I and II, and demobilization during                           
 completion of the project. Performed by contractor's                   
 permanent staff and recruitment personnel under                        
 supervision and direction of management elements I                     
 and II...............................................        4        6
VII. Expediting.-- Expediting contracting performed by                  
 contractor's staff and by subcontractors. Performed                    
 by contractor's staff under supervision and direction                  
 of elements I and II.................................        4        6
VIII. Construction equipment operations.-- This                         
 includes mobilization and demobilization. Performed                    
 by contractor's staff under supervision, direction                     
 and coordination of elements I, II, and IV...........        4        6
IX. Other services.-- Timekeeping, cost accounting,                     
 estimating, reporting, security, etc., by the                          
 contractor's staff under supervision and direction of                  
 elements I and II....................................        4        6
------------------------------------------------------------------------

    (d) Fee considerations dealing with the duration of a project are 
usually provided by the consideration given to the degree of complexity 
and magnitude of the work. In only very unusual circumstances should it 
be necessary to separately weight, positively or negatively, for the 
period of services or length of time involved in the project when 
determining fee levels.
    (e) The size of the operation is to a considerable degree a 
continuation of the complexity factor, and the degree and amount of work 
required to be performed by and with the contractor's own resources. 
Generally, no separate weighting, positively or negatively, is required 
for consideration of those factors.
    (f) The degree and amount of work required to be performed by and 
with the contractor's own resources affect the level of fees. Reasonable 
fees should be based on expectations of complete construction services 
normally associated with a construction or construction management 
contract. In the case of a construction contract, reduced services can 
be in the form of excessive subcontracting or supporting acquisition 
actions and labor relations interfaces being made by the government. If 
an unusual amount of such work is performed by other than the 
contractor, it will be necessary to make downward adjustments in the fee 
levels to provide for the reduction in services required.
    (g) The type of contract to be negotiated and the anticipated 
contractor cost risk shall be considered in establishing the appropriate 
fee objective for the contract.
    (h) When a contract calls for the contractor to use its own 
resources, including facilities and equipment, and to make its own cost 
investment (i.e., when there is no letter-of-credit financing), a 
positive impact on the fee amount shall be reflected.
[49 FR 11955, Mar. 28, 1984, as amended at 58 FR 36365, July 7, 1993; 59 
FR 9105, Feb. 25, 1994]



915.971-5  Fee schedules.

    (a) The schedules included in this paragraph, adjusted in accordance 
with provisions stated herein and 915.971-6, provide maximum fee levels 
for construction and construction management contracts. The fees are 
related to the estimated cost (fee base) for the construction work and 
services to be performed. The schedule in paragraph (d) sets forth the 
basic fee schedule for construction contracts. The schedule in paragraph 
(f) sets forth the basic fee schedule for construction management 
contracts. A separate schedule in paragraph (h) has been developed (i) 
for determining the fee applicable to special equipment purchases and 
(ii) to reflect a differing level of fee consideration associated with 
the subcontractor effort

[[Page 298]]

under construction management contracts. (See 915.971-6(c) and 915.971-
6(d)).
    (b) The schedules cited in paragraph (a) above provides the maximum 
fee amount for a CPFF contract arrangement. If a fixed-price type 
contract is to be awarded, the fee amount set forth in the fee schedules 
shall be increased by an amount not to exceed 4 percent of the fee base.
    (c) The fee schedule shown in paragraphs (d) and (f) assumes a 
letter of credit financing arrangement. If a contract provides for or 
requires the contractor to make their own cost investment for contract 
performance (i.e., when there is no letter-of-credit financing), the fee 
amounts set forth in the fee schedules shall be increased by an amount 
equal to 5 percent of the fee amount as determined from the schedules.
    (d) The following schedule sets forth the base for construction 
contracts:

                     Construction Contracts Schedule                    
------------------------------------------------------------------------
                                            Fee        Fee       Incr.  
           Fee base (dollars)            (dollars)  (percent)  (percent)
------------------------------------------------------------------------
100,000................................      5,400      5.40       5.30 
300,000................................     16,000      5.33       5.00 
500,000................................     26,000      5.20       4.80 
1,000,000..............................     50,000      5.00       3.55 
3,000,000..............................    121,000      4.03       3.00 
5,000,000..............................    181,000      3.62       2.62 
10,000,000.............................    312,000      3.12       2.38 
15,000,000.............................    431,000      2.87       2.01 
25,000,000.............................    632,000      2.53       1.79 
40,000,000.............................    900,000      2.25       1.58 
60,000,000.............................  1,216,000      2.03       1.43 
80,000,000.............................  1,502,000      1.88       1.29 
100,000,000............................  1,759,000      1.76       1.15 
150,000,000............................  2,333,000      1.56       0.99 
200,000,000............................  2,829,000      1.41       0.73 
300,000,000............................  3,563,000      1.19       0.63 
400,000,000............................  4,188,000      1.05       0.52 
500,000,000............................  4,706,000      0.94            
Over $500 million......................  4,706,000  .........  \1\ 0.52 
------------------------------------------------------------------------
\1\ 0.52% excess over $500 million.                                     

    (e) When using the Construction Contracts Schedule for establishing 
maximum payable basic fees, the following adjustments shall be made to 
the Schedule fee amounts for (1) complexity levels, (2) excessive 
subcontracting, (3) normal contractor services performed by the 
government or another contractor:
    (i) The target fee amounts, set forth in the fee schedule, shall not 
be adjusted for a Class A project, which is maximum complexity. A Class 
B project requires a 10 percent reduction in amounts. Class C and D 
projects require a 20 percent and 30 percent reduction, respectively. 
The various classes are defined in 915.971-4(b).
    (ii) The target fee schedule provides for 45 percent of the contract 
work to be subcontracted for such things as electrical and other 
specialties. Excessive subcontracting results when such efforts exceed 
45 percent of the total contract work. To establish appropriate fee 
reductions for excessive subcontracting, the negotiating official should 
first determine the amount of subcontracting as a percentage of the 
total contract work. Next, the negotiating official should determine a 
percentage by which the prime contractor's normal requirement (based on 
a requirement for doing work with its own forces) is reduced due to the 
excessive subcontracting and, finally, multiply the two percentages to 
determine a fee reduction factor.
    (iii) If acquisition or other services normally expected of the 
contractor (see 915.971-4(c)) are performed by the government, or 
another DOE prime or operating contractor, a fee reduction may also be 
required. The negotiating official should first determine what 
percentage of the total procurement or other required services is 
performed by others. Then the negotiating official should apply this 
percentage reduction to the normally assigned weightings for the 
management services or effort as discussed in 915.971-4(c) to arrive at 
the appropriate reduction factor.
    (f) The following schedule sets forth the base for construction 
management contracts:

               Construction Management Contracts Schedule               
------------------------------------------------------------------------
                                            Fee        Fee       Incr.  
           Fee base (dollars)            (dollars)  (percent)  (percent)
------------------------------------------------------------------------
100,000................................      5,400      5.40       5.30 
300,000................................     16,000      5.33       5.00 
500,000................................     26,000      5.20       4.80 
1,000,000..............................     50,000      5.00       3.55 
3,000,000..............................    121,000      4.03       3.00 
5,000,000..............................    181,000      3.62       2.62 
10,000,000.............................    312,000      3.12       2.38 
15,000,000.............................    431,000      2.87       2.01 
25,000,000.............................    632,000      2.53       1.79 
40,000,000.............................    900,000      2.25       1.58 
60,000,000.............................  1,216,000      2.03       1.43 
80,000,000.............................  1,502,000      1.88       1.29 
100,000,000............................  1,759,000      1.76   .........

[[Page 299]]

                                                                        
Over $100 million......................  1,759,000  .........  \1\ 1.29 
------------------------------------------------------------------------
\1\ 1.29% excess over $100 million.                                     

    (g) When applying the basic Construction Management Contracts 
Schedule for determining maximum payable fees, no adjustments are 
necessary to such payable fees for contractor Force account labor used 
for work which should otherwise be subcontracted until such Force 
account work exceeds, in the aggregate, 20 percent of the base. 
Excessive use of Force account work results when such effort exceeds 20 
percent of the fee base; and, when this occurs, appropriate fee 
reductions for such excessive Force account labor shall be computed as 
follows:
    (1) Determine the percentage amount of Force account work to total 
contractor effort.
    (2) Determine the percentage amount of subcontract work reduced due 
to the use of Force account work.
    (3) Multiply the two percentages to determine the fee reduction 
factor. It is not expected that reductions in the Construction 
Management Contracts Schedule fee amounts will be made for complexity, 
reduced requirements and similar adjustments as made for construction 
contracts.
    (h) The schedule of fees for consideration of special equipment 
purchases and for consideration of the subcontract program under a 
construction management contract is as follows:

          Special Equipment Purchases/Subcontract Work Schedule         
------------------------------------------------------------------------
                                            Fee        Fee       Incr.  
           Fee base (dollars)            (dollars)  (percent)  (percent)
------------------------------------------------------------------------
100,000................................      1,500      1.50       1.50 
200,000................................      3,000      1.50       1.50 
400,000................................      6,000      1.50       1.50 
600,000................................      9,000      1.50       1.50 
800,000................................     12,000      1.50       1.50 
1,000,000..............................     15,000      1.50       1.00 
2,000,000..............................     25,000      1.25       0.85 
4,000,000..............................     42,000      1.05       0.70 
6,000,000..............................     56,000      0.93       0.65 
8,000,000..............................     69,000      0.86       0.60 
10,000,000.............................     81,000      0.81       0.56 
15,000,000.............................    109,000      0.73       0.48 
25,000,000.............................    157,000      0.63       0.43 
40,000,000.............................    222,000      0.56       0.40 
60,000,000.............................    301,000      0.50       0.36 
80,000,000.............................    372,000      0.47       0.34 
100,000,000............................    439,000      0.44       0.25 
150,000,000............................    566,000      0.38       0.21 
200,000,000............................    670,000      0.34       0.12 
300,000,000............................    793,000      0.26   .........
Over $300 million......................    793,000  .........  \1\ 0.12 
------------------------------------------------------------------------
\1\ 0.12% excess over $300 million.                                     

[49 FR 11955, Mar. 28, 1984, as amended at 56 FR 28101, June 19, 1991]



915.971-6  Fee base.

    (a) The fee base shown in the Construction Contracts Schedule and 
Construction Management Contracts Schedule represents that estimate of 
cost to which a percentage factor is applied to determine maximum fee 
allowances. The fee base is the estimated necessary allowable cost of 
the construction work or other services which are to be performed. It 
shall include the estimated cost for, but is not limited to, the 
following as they may apply in the case of a construction or 
construction management contract:
    (1) Site preparation and utilities.
    (2) Construction (labor-materials-supplies) of buildings and 
auxiliary facilities.
    (3) Construction (labor-materials-supplies) to complete/construct 
temporary buildings.
    (4) Design services to support the foregoing.
    (5) General management and job planning cost.
    (6) Labor supervision.
    (7) Procurement and acquisition administration.
    (8) Construction performed by subcontractors.
    (9) Installation of government furnished or contractor acquired 
special equipment and other equipment.
    (10) Equipment (other than special equipment) which is to become 
Government property (including a component of Government property).
    (b) The fee base for the basic fee determination for a construction 
contract and construction management contract shall include all 
necessary

[[Page 300]]

and allowable costs cited in paragraph (a) of this section as 
appropriate to the type of contract; except, any home office G&A expense 
paid as a contract cost per cost principle guidance and procedures shall 
be excluded from the fee base. The fee base shall exclude:
    (1) Cost of land.
    (2) Cost of engineering (A&E work).
    (3) Contingency estimate.
    (4) Equipment rentals or use charges. (See 936.70.)
    (5) Cost of government furnished equipment or materials.
    (6) Special equipment as defined in 936.7201.
    (c) A separate fee base shall be established for special equipment 
for use in applying the Special Equipment Purchases or Subcontract Work 
Schedule (see 915.971-5(h)). The fee base for determination of 
applicable fees on special equipment shall be based on the estimated 
purchase price of the equipment.
    (d) The fee base under the Construction Management Contracts 
Schedule for a maximum basic fee determination for a construction 
management contract shall be comprised of only the costs of the 
construction manager's own efforts. However, it is recognized that in 
the case of construction management contracts, the actual construction 
work will be performed by subcontractors. In most cases the subcontract 
awards for the construction work will be made by the construction 
management contractor. Occasionally the contract may involve management 
of construction performed under a contract awarded by the Department or 
by one of the Department's operating contractors. In these cases, the 
actual cost of the subcontracted construction work shall be excluded 
from the fee base used to determine the maximum basic fee (under the 
Construction Management Contracts Schedule) applicable to a construction 
management contract. A separate fee base for additional allowances 
(using the Special Equipment Purchases or Subcontract Work Schedule) 
shall be established, which shall be comprised of those subcontract 
construction costs, special equipment purchases, and other items' costs 
that are contracted for or purchased by the construction manager.
[49 FR 11955, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984; 58 FR 36365, 
July 7, 1993]



915.972  Special considerations for cost-plus-award-fee contracts.

    (a) When a contract is to be awarded on a cost-plus-award-fee basis 
in accordance with 916.404-2, several special considerations are 
appropriate. Fee objectives for management and operating contracts, 
including those using the Construction or Construction Management fee 
schedules from section 915.971-5, shall be developed pursuant to the 
procedures set forth in section 970.1509-8. Fee objectives for other 
cost-plus-award-fee contracts shall be developed as follows:
    (1) The base fee portion of the fee objective of an award fee 
contract may range from 0% up to the 50% level of the fee amount for a 
Cost-Plus-Fixed-Fee (CPFF) contract, arrived at by using the weighted 
guidelines or other techniques (such as those provided in 915.971 for 
construction and construction management contracts). However, the base 
amount should not normally exceed 50% of the otherwise applicable fixed 
fee. In the event this 50% limit is exceeded, appropriate documentation 
shall be entered into the contract file. In no event shall the base fee 
exceed 60% of the fixed fee amount.
    (2) The base fee plus the amount included in the award fee pool 
should normally not exceed the fixed fee (as subjectively determined or 
as developed from the fee schedule) by more than 50%. However, in the 
event the base fee is to be less than 50% of the fixed fee, the maximum 
potential award fee may be increased proportionately with the decreases 
in base fee amounts.
    (3) The following maximum potential award fees shall apply in award 
fee contracts: (percent is stated as percent of fee schedule amounts).

                                                                        
------------------------------------------------------------------------
                                          Award fee      Maximum total  
           Base fee percent                percent         percentage   
------------------------------------------------------------------------
50....................................      100              150        
40....................................      120              160        
30....................................      140              170        
20....................................      160              180        
10....................................      180              190        

[[Page 301]]

                                                                        
0.....................................      200              200        
------------------------------------------------------------------------

    (b) Prior approval of the Procurement Executive, is required for 
total fee (base plus award fee pool) exceeding the guidelines in 
915.972(a)(3). Additionally, in the event use of the award fee 
guidelines exceeds the statutory limitations discussed in FAR 
15.903(d)(1) (i), (ii) and (iii), prior approval of the Procurement 
Executive shall also be required.
[49 FR 11955, Mar. 28, 1984, as amended at 56 FR 28101, June 19, 1991]



Subpart 915.10--Preaward, Award, and Postaward Notifications, Protests, 
                              and Mistakes



915.1003  Debriefings of unsuccessful offerors.

    (a) Debriefings must be requested within 10 working days of receipt 
of notification of elimination from consideration or announcement of 
selection. Contracting officers shall advise unsuccessful offerors of 
this limitation in such notification letter(s). Debriefings will be 
provided at the earliest feasible time, which normally shall be after 
announcement of the selection decision and prior to award of the 
contract. However, when the exigency of the situation will not permit 
delaying the award in order to debrief unsuccessful offerors, such 
debriefing may be conducted after award of the contract. The contracting 
officer may, if it is decided the facts justify such action, receive and 
act upon a request received at a later date. Also see 924.202(b).
[49 FR 11955, Mar. 28, 1984; 49 FR 38950, Oct. 2, 1984. Redesignated at 
50 FR 12185, Mar. 27, 1985; 59 FR 9105, Feb. 25, 1994]



PART 916--TYPES OF CONTRACTS--Table of Contents




                  Subpart 916.2--Fixed-Price Contracts

Sec.
916.203  Fixed-price contracts with economic price adjustments.
916.203-4  Contract clauses.

               Subpart 916.3--Cost-Reimbursement Contracts

916.306  Cost-plus-fixed-fee contracts.
916.307  Contract clauses.

                   Subpart 916.4--Incentive Contracts

916.404-2  Cost-plus-award-fee contracts.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11972, Mar. 28, 1984, unless otherwise noted.



                  Subpart 916.2--Fixed-Price Contracts



916.203  Fixed-price contracts with economic price adjustments.



916.203-4  Contract clauses.

    (d)(2) The Head of the Contracting Activity, or designee, for 
contracts estimated to be within the limits of their delegated 
authority, may approve the use of an economic price adjustment clause 
when appropriate in accordance with (FAR) 48 CFR 16.203-4.
[49 FR 11955, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



               Subpart 916.3--Cost-Reimbursement Contracts



916.306  Cost-plus-fixed-fee contracts.

    (c)(2) The Head of the Contracting Activity, or designee, for 
contracts estimated to be within their delegated authority, may approve 
(sign) the determination and findings establishing the basis for 
application of the statutory price or fee limitations.
[49 FR 11955, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



916.307  Contract clauses.

    (j) The contracting officer shall insert the clause at FAR 52.216-
15, Predetermined Indirect Cost Rates, modified as specified in 952.216-
15 in solicitations and contracts when a cost-reimbursement research and 
development contract with a State or local government is contemplated 
and predetermined indirect cost rates are to be used.

[[Page 302]]



                   Subpart 916.4--Incentive Contracts



916.404-2  Cost-plus-award-fee contracts.

    (d) Fee Determination Plans. Award fee arrangements limited to 
technical performance considerations are prohibited because they may 
increase cost disproportionately to any benefits gained. Instead, the 
award fee arrangement shall include both technical performance 
(including scheduling as appropriate) and business management 
considerations tailored to the needs of the particular situation. In 
addition, in a situation where cost estimating reliability and other 
factors are such that the negotiation of a separate predetermined 
incentive sharing arrangement applicable to cost performance is 
determined both feasible and advantageous, cost incentives may be added. 
The resulting contract would then be identified as a cost-plus-
incentive-fee/award-fee combination type. The goals and evaluation 
criteria should be results-oriented. The award fee should be 
concentrated on the end product of the contract, that is, output, be it 
hardware, research and development, demonstration or services, together 
with business management considerations. However, input criteria such as 
equal employment opportunity, small business programs, functional 
management areas, such as safety, security, etc., should not be 
disregarded and may be appropriate criteria upon which to base some part 
of the award fee. Specific goals or objectives shall be established in 
relation to each performance evaluation criterion against which 
contractor performance is measured.
[49 FR 11955, Mar. 28, 1984, as amended at 59 FR 9105, Feb. 25, 1994]



PART 917--SPECIAL CONTRACTING METHODS--Table of Contents




            Subpart 917.6--Management and Operating Contracts

Sec.
917.600  Scope of subpart.
917.601  Definitions.
917.602  Policy.
917.604  Identifying management and operating contracts.
917.605  Award, renewal, and extension.

                   Subpart 917.70--Cost Participation

917.7000  Scope of subpart.
917.7001  Policy.

       Subpart 917.72--Program Opportunity Notices for Commercial 
                             Demonstrations

917.7200  Scope of subpart.
917.7201  Policy.
917.7201-1  General.

     Subpart 917.73--Program Research and Development Announcements

917.7300  Scope of subpart.
917.7301  Policy.
917.7301-1  General.

      Subpart 917.74--Acquisition, Use, and Disposal of Real Estate

917.7401  General.
917.7402  Policy.
917.7403  Application.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11974, Mar. 28, 1984, unless otherwise noted.



            Subpart 917.6--Management and Operating Contracts



917.600  Scope of subpart.

    This subpart implements FAR Subpart 17.6, Management and Operating 
Contracts. DOE implementing procedures and requirements to be followed 
in the selection, award, and administration of Management and Operating 
Contracts are at part 970. The requirements of this subpart apply to any 
Department of Energy management and operating contract, including 
performance-based management contracts as defined in 48 CFR (DEAR) 
917.601. References in this subpart to ``management and operating 
contracts'' shall be understood to include ``performance-based 
management contracts.''
[49 FR 11974, Mar. 28, 1984, as amended at 62 FR 34861, June 27, 1997]



917.601  Definitions.

    Performance-based contracting means structuring all aspects of an 
acquisition around the purpose of the work to be performed as opposed to 
the manner by which the work is to be performed

[[Page 303]]

or broad or imprecise statements of work.
    Performance-based management contract means a management and 
operating contract that employs, to the maximum extent practicable, 
performance-based contracting concepts and methodologies through the 
application of results-oriented statements of work; clear objective 
performance standards and measurement tools; and incentives to encourage 
superior contractor performance.
[62 FR 34861, June 27, 1997]



917.602  Policy.

    (a) It is the policy of the Department of Energy to provide for full 
and open competition in the award of management and operating contracts, 
including performance-based management contracts.
    (b) A management and operating contract may be awarded or extended 
at the completion of its term without providing for full and open 
competition only when such award or extension is justified under one of 
the statutory authorities identified in FAR 6.302 and only when 
authorized by the Head of the Agency. Documentation and processing 
requirements for justifications for the use of other that full and open 
competition shall be accomplished in accordance with internal agency 
procedures.
[61 FR 32586, June 24, 1996]



917.604  Identifying management and operating contracts.

    (a) Single purpose contracts for the operation of process 
development units, pilot plants, and demonstration plants where the 
purpose is to demonstrate the viability of processes toward the goal of 
commercialization are not considered to be included, unless designated 
operating contracts in accordance with FAR 17.602.



917.605  Award, renewal, and extension.

    Conditional Authorization of Non-competitive Extension Made Pursuant 
to Authority Under CICA. Authorization to extend by the Head of the 
Agency shall be considered conditional upon the successful negotiation 
of the contract to be extended in accordance with the Department's 
negotiation objectives. The Head of the Contracting Activity shall 
advise the Procurement Executive no later than 6 months after receipt of 
the conditional authorization as to whether the Department's objectives 
will be met and, if not, the contracting activity's plans for competing 
the requirement.
[61 FR 32586, June 24, 1996]



                   Subpart 917.70--Cost Participation

    Source:  61 FR 41706, Aug. 9, 1996, unless otherwise noted.



917.7000  Scope of subpart.

    (a) This subpart sets forth the DOE policy on cost participation by 
organizations performing research, development, and/or demonstration 
projects under DOE prime contracts. This subpart does not cover efforts 
and projects performed for DOE by other Federal agencies.
    (b) Cost participation is a generic term denoting any situation 
where the Government does not fully reimburse the performer for all 
allowable costs necessary to accomplish the project or effort under the 
contract. The term encompasses cost sharing, cost matching, cost 
limitation (direct or indirect), participation in kind, and similar 
concepts.



917.7001  Policy.

    (a) When DOE supports performer research, development, and/or 
demonstration efforts, where the principal purpose is ultimate 
commercialization and utilization of the technologies by the private 
sector, and when there are reasonable expectations that the performer 
will receive present or future economic benefits beyond the instant 
contract as a result of performance of the effort, it is DOE policy to 
obtain cost participation. Full funding may be provided for early phases 
of development programs when the technological problems are still great.

[[Page 304]]

    (b) In making the determination to obtain cost participation, and 
evaluating present and future economic benefits to the performer, DOE 
will consider the technical feasibility, projected economic viability, 
societal and political acceptability of commercial application, as well 
as possible effects of other DOE-supported projects in competing 
technologies.
    (c) The propriety, manner, and amount of cost participation must be 
decided on a case-by-case basis.
    (d) Cost participation is required for demonstration projects unless 
exempted by the Under Secretary. Demonstration projects, pursuant to 
this subpart, include demonstrations of technological advances and field 
demonstrations of new methods and procedures, and demonstrations of 
prototype commercial applications for the exploration, development, 
production, transportation, conversion, and utilization of energy 
resources.



       Subpart 917.72--Program Opportunity Notices for Commercial 
                             Demonstrations

    Source:  61 FR 41706, Aug. 9, 1996, unless otherwise noted.



917.7200  Scope of subpart.

    (a) This subpart discusses the policy for the use of a program 
opportunity notice solicitation approach to accelerate the demonstration 
of the technical feasibility and commercial application of all 
potentially beneficial non-nuclear energy sources and utilization 
technologies.
    (b) This subpart applies to demonstrations performed by individuals, 
educational institutions, commercial or industrial organizations, or 
other private entities, public entities, including State and local 
governments, but not other Federal agencies. For purposes of this 
subpart, commercial demonstration projects include demonstrations of 
technological advances, field demonstrations of new methods and 
procedures, and demonstration of prototype commercial applications for 
the exploration, development, production, transportation, conversion, 
and utilization of non-nuclear energy resources.



917.7201  Policy.



917.7201-1  General.

    (a) It is DOE's intent to encourage the submission of proposals to 
accelerate the demonstration of the technical, operational, economic, 
and commercial feasibility and environmental acceptability of particular 
energy technologies, systems, subsystems, and components. Program 
opportunity notices will be used to provide information concerning 
scientific and technological areas encompassed by DOE's programs. DOE 
shall, from time to time, issue program opportunity notices for 
proposals for demonstrations of various forms of non-nuclear energy and 
technology utilization.
    (b) Each program opportunity notice shall as a minimum describe: the 
goal of the intended demonstration effort; the time schedule for award; 
evaluation criteria; program policy factors; the amount of cost detail 
required; and proposal submission information. Program policy factors 
are those factors which, while not appropriate indicators of a 
proposal's individual merit (i.e., technical excellence, proposer's 
ability, cost, etc.), are relevant and essential to the process of 
choosing which of the proposals received will, taken together, best 
achieve the program objectives. All such factors shall be predetermined 
and specified in the notice so as to notify proposers that factors which 
are essentially beyond their control will affect the selection process.



     Subpart 917.73--Program Research and Development Announcements

    Source:  61 FR 41707, Aug. 9, 1996, unless otherwise noted.



917.7300  Scope of subpart.

    (a) This subpart discusses the policy for the use of a program 
research and development announcement (PRDA) solicitation approach to 
obtain and select proposals from the private sector for the conduct of 
research, development, and related activities in the energy field.

[[Page 305]]



917.7301  Policy.



917.7301-1  General.

    (a) PRDAs shall be used to provide potential proposers with 
information concerning DOE's interest in entering into arrangements for 
research, development, and related projects in specified areas of 
interest. It is DOE's intent to solicit the submission of ideas which 
will serve as a basis for research, development, and related activities 
in the energy field. It is DOE's desire to encourage the involvement of 
small business concerns, small disadvantage business concerns, and 
women-owned small business concerns in research and development 
undertaken pursuant to PRDAs.
    (b) The PRDA should not replace existing acquisition procedures 
where a requirement can be sufficiently defined for solicitation under 
standard advertised or negotiated acquisition procedures. Similarly, it 
should not inhibit or curtail the submission of unsolicited proposals. 
However, a proposal which is submitted as though it were unsolicited but 
is in fact germane to an existing PRDA shall be treated as though 
submitted in response to the announcement or returned without action to 
the proposer, at the proposer's option. Further, the PRDA is not to be 
used in a competitive situation where it is appropriate to negotiate a 
study contract to obtain analysis and recommendations to be incorporated 
in the subsequent request for proposals.
    (c) The PRDA is to be used only where:
    (1) Research and development is required in support of a specific 
project area within an energy program with the objective of advancing 
the general scientific and technological base, and this objective is 
best achieved through:
    (i) A diversity of possible approaches, within the current state of 
the art, available for solving the problems;
    (ii) The involvement of a broad spectrum of organizations in seeking 
out solutions to the problems posed;
    (iii) The application of the unique qualifications or specialized 
capabilities of many individual proposers which will enable them to 
perform portions of the research project (without necessarily possessing 
the qualifications to perform the entire project) so that the overall 
support may be broken into segments which cannot be ascertained in 
advance; and,
    (iv) The fostering of new and creative solutions.
    (2) Consistent with paragraph (c)(1) of this section, it is 
anticipated that choices will have to be made among dissimilar concepts, 
ideas, or approaches; and
    (3) It is determined that a broad range of organizations exist that 
would be capable of contributing towards the overall research and 
development goals identified in paragraph (c)(1) of this section.
    (d) Each PRDA shall as a minimum describe: the area(s) of program 
interest; time schedule for award; proposal submittal information; 
evaluation criteria; and program policy factors. The PRDA should clearly 
emphasize to proposers that program policy factors are essentially 
beyond their control and will affect the selection process. The PRDA 
should also state that DOE reserves the right to select for award or 
support any, all, or none of the proposals received in response to an 
announcement.



      Subpart 917.74--Acquisition, Use, and Disposal of Real Estate

    Source:  61 FR 41707, Aug. 9, 1996, unless otherwise noted.



917.7401  General.

    Special circumstances and situations may arise under cost-type 
contracts when, in the performance of the contract or subcontract, the 
performer shall be required, or otherwise find it necessary, to acquire 
real estate or interests therein by:
    (a) Purchase, on DOE's behalf or in its own name, with title 
eventually vesting in the Government.
    (b) Lease, and DOE assumes liability for, or otherwise will pay for 
the obligation under the lease.
    (c) Acquisition of temporary interest through easement, license or 
permit, and DOE funds the cost of the temporary interest.

[[Page 306]]



917.7402  Policy.

    It is the policy of the Department of Energy that, when real estate 
acquisitions are made, the following policies and procedures shall be 
applied to such acquisitions:
    (a) Real estate acquisitions shall be mission essential; 
effectively, economically, and efficiently managed and utilized; and 
disposed of promptly, when not needed;
    (b) Acquisitions shall be justified, with documentation which 
describes the need for the acquisitions, general requirements, cost, 
acquisition method to be used, site investigation reports, site 
recommended for selection, and property appraisal reports; and
    (c) Acquisition by lease, in addition to the requirements in 
paragraphs (a) and (b) of this section:
    (1) Shall not exceed a one-year term if funded by one-year 
appropriations.
    (2) May exceed a one-year term, when the lease is for special 
purpose space funded by no-year appropriations and approved by the 
Department.
    (3) Shall contain an appropriate cancellation clause which limits 
the Government's obligation to no more than the amount of rent to the 
earliest cancellation date plus a reasonable cancellation payment.
    (4) Shall be consistent with Government laws and regulations 
applicable to real estate management.



917.7403  Application.

    The clause at 48 CFR 952.217-70 shall be included in contracts or 
modifications where contractor acquisitions are expected to be made.

[[Page 307]]



                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS





PART 919--SMALL BUSINESS PROGRAMS--Table of Contents




                         Subpart 919.2--Policies

Sec.
919.201  General policy.

              Subpart 919.5--Set-Asides for Small Business

919.501  General.
919.502-2  Total set-asides.
919.503  Setting aside a class of acquisitions.

    Subpart 919.6--Certificates of Competency and Determinations of 
                               Eligibility

919.602-1  Referral.

 Subpart 919.7--Subcontracting With Small Business, Small Disadvantaged 
            Business, and Women-Owned Small Business Concerns

919.705-6  Postaward responsibilities of the contracting officer.

 Subpart 919.8--Contracting With the Small Business Administration (The 
                              8(a) Program)

919.805-2  Procedures.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11997, Mar. 28, 1984, unless otherwise noted.



                         Subpart 919.2--Policies



919.201  General policy.

    (c) The Director, Office of Small and Disadvantaged Business 
Utilization, Headquarters, is responsible for the administration of the 
DOE small, small disadvantaged, and women-owned small business programs. 
The Executive Director, Federal Energy Regulatory Commission, is 
responsible for the administration of the Commission's small, small 
disadvantaged, and women-owned small business programs. This includes 
responsibility for developing, implementing, executing, and managing 
these programs, providing advice on these programs, and representing DOE 
before other Government agencies on matters primarily affecting small, 
small disadvantaged, and women-owned small businesses. The Heads of 
Contracting Activities (HCAs) shall appoint a small business specialist.
[50 FR 12185, Mar. 27, 1985, as amended at 59 FR 9106, Feb. 25, 1994; 61 
FR 21976, May 13, 1996]



              Subpart 919.5--Set-Asides for Small Business



919.501  General.

    (c) The Department has established an internal comprehensive review 
and screening process for acquisitions exceeding the simplified 
acquisition threshold. The review is intended to enhance the prospect of 
participation by small business, small disadvantaged business, and 
women-owned small business concerns.
    (g) The policy prescribed by FAR 19.501(g), which requires that a 
product or service acquired by a successful small business set-aside 
shall continue to be acquired on a set-aside basis, is applicable to DOE 
on a contracting activity-wide basis. The small and disadvantaged 
business specialist at a contracting activity shall maintain a list of 
such small business set-aside awards.
[52 FR 38425, Oct. 16, 1987, as amended at 59 FR 9106, Feb. 25, 1994; 61 
FR 21977, May 13, 1996]



919.502-2  Total set-asides.

    In considering set-asides in the area of architect engineer 
contracts, contracting personnel must first consider the special 
procedures required by the Brooks Act, Pub. L. 92-582 pertaining to this 
type acquisition.



919.503  Setting aside a class of acquisitions.

    By agreement with SBA, the DOE has established a class set-aside for 
construction acquisitions not exceeding $3 million, including new 
construction and repair and alteration of structures. Lists of other 
class set-asides shall be maintained by all DOE contracting offices. 
These lists shall be updated at least annually.

[[Page 308]]



    Subpart 919.6--Certificates of Competency and Determinations of 
                               Eligibility



919.602-1  Referral.

    (a)(2) The contracting officer shall coordinate with the small 
business specialist and the SBA procurement center representative prior 
to referring a determination of nonresponsibility of a small business to 
the SBA Regional Office.
[52 FR 38425, Oct. 16, 1987, as amended at 61 FR 21977, May 13, 1996]



 Subpart 919.7--Subcontracting With Small Business, Small Disadvantaged 
            Business, and Women-Owned Small Business Concerns



919.705-6  Postaward responsibilities of the contracting officer.

    A copy of the notification to the SBA of awards of contracts, 
amendments or modifications that contain subcontracting plans, as 
required by FAR 19.705-6(a), shall be provided to the Office of Small 
and Disadvantaged Business Utilization.
[49 FR 11997, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



 Subpart 919.8--Contracting With the Small Business Administration (The 
                              8(a) Program)



919.805-2  Procedures.

    Acquisitions involving section 8(a) competition are exempt from 
Department of Energy formal Source Evaluation Board procedures cited in 
subpart 915.6, Source Selection, but must still comply with source 
selection procedures set forth in the FAR in accordance with 13 CFR 
124.311(f)(1).
[56 FR 42947, Aug. 30, 1991]



PART 922--APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITION--Table of Contents




                   Subpart 922.1--Basic Labor Policies

Sec.
922.103  Overtime.
922.103-4  Approvals.
922.103-5  Contract clauses.

            Subpart 922.6--Walsh-Healey Public Contracts Act

922.608-3  Protests against eligibility.
922.608-4  Award pending final determination.
922.608-5  Award.
922.608-6  Postaward.

               Subpart 922.8--Equal Employment Opportunity

922.800  Scope of subpart.
922.802  General.
922.803  Responsibilities.
922.804  Affirmative action programs.
922.804-1  Nonconstruction.
922.804-2  Construction.
922.807  Exemptions.

    Supbart 922.71--Whistleblower Protection for Contractor Employees

922.7100  General.
922.7101  Clause.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 11998, Mar. 28, 1984, unless otherwise noted.



                   Subpart 922.1--Basic Labor Policies



922.103  Overtime.



922.103-4  Approvals.

    (d) Approvals. (1) Where the cost to the Government may be affected, 
approval of hours of work in excess of the normal workweek is justified 
only in those instances and for those employees where it can be shown 
that overtime would provide needed and demonstrable impetus to the 
accomplishment of DOE objectives and that all other means of meeting 
these objectives have been considered and found inadequate or not 
feasible. Accordingly, the Heads of Contracting Activities shall:
    (i) Establish controls to prevent excess casual overtime and to 
assure that such overtime work is in the best interest of the 
Government. Casual overtime means (A) work in excess of the normal 
workweek (or in excess of an authorized extended workweek) which cannot 
be regularly scheduled in advance, or (B) regularly scheduled work in 
excess of the normal workweek for a period of four consecutive weeks or 
less; and

[[Page 309]]

    (ii) Establish controls to assure that any use of any extended 
workweek schedule is in the best interest of the Government. Extended 
workweek means a workweek regularly scheduled and established in excess 
of the normal workweek for a period in excess of four consecutive weeks.
[49 FR 11998, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



922.103-5  Contract clauses.

    In accordance with FAR 22.101-1(e) and FAR 22.103-5, the contracting 
officer shall insert the clause at FAR 52.222-1, Notice to the 
Government of Labor Disputes, in all solicitations and contracts for 
protective services at DOE owned facilities requiring continuity of 
services for public safety and national security reasons. The 
contracting officer may insert this clause in other solicitations and 
contracts where a significant need for continuity in contract 
performance exists. See 937.70, Protective Services Contracting, for 
additional policy guidance regarding protective services.
[58 FR 36151, July 6, 1993]



            Subpart 922.6--Walsh--Healey Public Contracts Act



922.608-3  Protests against eligibility.

    When an eligibility determination made by the contracting officer is 
challenged, this protest shall be handled in accordance with procedures 
for agency protests against award, except the matter shall be submitted 
to the Department of Labor for final determination. However, if the 
eligibility determination challenged pertains to a small business, the 
protest shall be forwarded to the Small Business Administration for 
determination.



922.608-4  Award pending final determination.

    (a) Award, as contemplated by FAR 22.608-4, may be made only with 
the approval of the Head of the Contracting Activity.



922.608-5  Award.

    The notice required by (FAR) 48 CFR 22.608-5 is to be sent to the 
appropriate Department of Labor Regional Office in which the contractors 
place of business is located. Regional Office locations are specified at 
FAR 22.609.
[49 FR 11998, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



922.608-6  Postaward.

    (c) Any postaward actions of the type discussed at FAR 22.608-6 
should be coordinated in advance with the Office of Industrial 
Relations, Headquarters.



               Subpart 922.8--Equal Employment Opportunity



922.800  Scope of subpart.

    This subpart implements (FAR) 48 CFR part 22, subpart 22.8. It 
applies to all DOE contracts and subcontracts.
[49 FR 11998, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



922.802  General.



922.803  Responsibilities.

    (a) The Director, Office of Federal Contract Compliance Programs of 
the Department of Labor has been delegated authority and responsibility 
for carrying out the requirements of Executive Order 11246, as amended. 
In conjunction with the delegation, contracting officers shall be 
familiar with existing and any updated provisions of 41 CFR Ch. 60, and 
assist the Department of Labor in its compliance responsibilities. DOE 
contracting officers will include the applicable Equal Employment 
Opportunity (EEO)) and Affirmative Action Program (AAP) requirements in 
their solicitations and obtain the applicable reports of compliance from 
the Office of Federal Contract Compliance Programs (OFCCP) (when 
required) prior to awarding of contracts. The provisions of 41 CFR Ch. 
60, are applicable to all DOE contracts.
    (d) The OFCCP requires that requests for pre-award clearances be 
directed to the OFCCP Regional Office in which the contractor's facility 
is (to be) located. If OFCCP finds the contractor in compliance, the 
contracting officer will be notified. Findings of non-compliance can be 
communicated to the contracting officer by the OFCCP or Headquarters 
Director or his designee. The appropriate Regional Office will

[[Page 310]]

provide the appropriate contact point in cases of non-compliance. The 
Director, Office of Civil Rights (DOE HQ), when requested, will provide 
assistance to contracting officers resolving non-compliance issues by 
providing assistance in obtaining a final decision from the OFCCP.
[49 FR 11998, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 58 
FR 36365, July 7, 1993]



922.804  Affirmative action programs.



922.804-1  Nonconstruction.

    In the event a prospective contractor or subcontractor is entering 
into its first contract containing the Equal Opportunity clause, the 
contracting officer shall determine that the prospective contractor 
understands and appears able to conform to the requirements of the EEO 
clause.



922.804-2  Construction.

    (a) Construction contracts, including cost-sharing contracts, are 
subject to OFCCP orders applicable in particular areas.
    (1) When a proposed nonexempt construction contract is within a 
geographic area where construction is subject to the provisions of 
Federal EEO Bid Conditions, Part I or Part II, the solicitation shall 
contain those bid conditions. The contracting officer shall include in 
such solicitation a provision that ``the offeror shall adhere to the 
affirmative action plan (bid conditions) set forth in this 
solicitation.''
    (2) Lists of areas for which OFCCP has designated specific 
affirmative action requirements are available through the Procurement 
Executive. Contracting officers should assure that this list and copies 
of pertinent orders are made available to all concerned DOE offices and 
to DOE contractors and construction subcontractors for work to be 
performed in the specified geographical areas.
    (b) Other nonexempt construction contracts. (1) When a proposed 
nonexempt construction contract is not in a ``plan area'' and is in the 
amount of $10,000 or more, offerors must agree to comply with the Equal 
Employment Opportunity clause.
    (2) When proposed nonexempt contracts of $1,000,000 or over are not 
in plan areas and have not been designated as high impact, offerors also 
must submit to the contracting officer details regarding specific 
affirmative action steps to be taken by the offeror in connection with 
all work under the contract. Such details shall include estimates of the 
percentage of minority group persons expected to be employed in each 
craft involved in the performance of the contract work. All 
solicitations for construction contracts shall reference the affirmative 
action requirements and the offeror's obligation to make good faith 
efforts to employ women in craft positions.
    (3) Pursuant to the OFCCP order dated August 30, 1976, agencies 
shall develop ``Special Bid Conditions'' for use on high impact projects 
in non-plan areas. These special bid conditions will include mandatory 
goals and timetables for the utilization of minorities. The Procurement 
Executive using the criteria issued by OFCCP will determine those 
projects that are ``high impact.'' The contracting officer is 
responsible for compliance with policies and procedures contained in the 
OFCCP ``Construction Compliance Program Operations Manual.'' Language 
for inclusion in solicitations or contracts contained in the manual may 
be modified, provided all of the requirements are retained. The 
contracting officer shall develop the goals and timetables and shall 
confer with the appropriate OFCCP regional office. The Office of Civil 
Rights will provide assistance as necessary, when requested. Special bid 
conditions will be submitted by the contracting officer to the 
appropriate OFCCP regional office for approval unless otherwise directed 
by the Procurement Executive. When special bid conditions are 
applicable, adequate presolicitation lead time should be allowed for 
submission of the special bid conditions to OFCCP national and regional 
offices.
    (c) An attempt to limit in any major respect the equal opportunity 
requirements included in an invitation for bids or request for proposals 
for a construction contract shall constitute grounds for a determination 
that the

[[Page 311]]

offeror does not qualify as a responsible offeror and for rejection of 
the bid or proposal. In the case of construction acquisition by DOE 
prime contractors, this determination shall be made only with the 
approval of the DOE contracting officer.
[49 FR 11998, Mar. 28, 1984, as amended at 56 FR 41965, Aug. 26, 1991, 
58 FR 36365, July 7, 1993; 59 FR 9106, Feb. 25, 1994]



922.807  Exemptions.

    (c) Contracting officer requests for exemption from E.O. 11246 
should be directed to the Procurement Executive for submission to the 
Director, OFCCP.



    Subpart 922.71--Whistleblower Protection for Contractor Employees



922.7100  General.

    The policy at 970.2274 also applies to contracts other than 
management and operating contracts that involve work to be performed on-
site at a DOE-owned or -leased facility.
[57 FR 57639, Dec. 4, 1993; 58 FR 39679, July 26, 1993]



922.7101  Clause.

    The contracting officer shall insert the clause at 970.5204-59, 
Whistleblower Protection for Contractor Employees, in contracts other 
than management and operating contracts that involve work to be 
performed on-site at a DOE-owned or -leased facility, after adding to 
the end of paragraph (a) of that clause, the phrase, ``with respect to 
work performed on-site at a DOE-owned or -leased facility, as provided 
for at 10 CFR part 708.'' The term ``work performed on-site'' is defined 
at 970.2274(c).
[57 FR 57639, Dec. 4, 1992; 58 FR 39679, July 26, 1993]



PART 923--ENVIRONMENT, CONSERVATION, OCCUPATIONAL SAFETY, AND DRUG FREE WORKPLACE--Table of Contents




                Subpart 923.4--Use of Recovered Materials

Sec.
923.471  Policy.

            Subpart 923.5--Workplace Substance Abuse Programs

923.570  Workplace substance abuse programs at DOE sites.
923.570-1  Applicability.
923.570-2  Solicitation provision and contract clause.
923.570-3  Suspension of payments, termination of contract, and 
          debarment and suspension actions.

  Subpart 923.70--Environmental, Conservation, and Occupational Safety 
                                Programs

923.7001  Nuclear safety.
923.7002  Contract clauses.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).



                Subpart 923.4--Use of Recovered Materials



923.471  Policy.

    The DOE policy is to acquire items composed of the highest 
percentage of recovered/recycled materials practicable (consistent with 
published minimum content standards), without adversely affecting 
performance requirements; consistent with maintaining a satisfactory 
level of competition; and consistent with maintaining cost effectiveness 
and not having a price premium paid for products containing recovered/
recycled materials.
[60 FR 47492, Sept. 13, 1995]



            Subpart 923.5--Workplace Substance Abuse Programs

    Source:  57 FR 32676, July 22, 1992, unless otherwise noted.



923.570  Workplace substance abuse programs at DOE sites.

    (a) The Department of Energy (DOE), as part of its overall 
responsibilities to protect the environment, maintain public health and 
safety, and safeguard the national security, has established policies, 
criteria, and procedures for contractors to develop and implement 
programs that help maintain a workplace free from the use of illegal 
drugs.
    (b) Regulations concerning DOE's contractor workplace substance 
abuse programs are promulgated at 10 CFR part 707, Workplace Substance 
Abuse Programs at DOE Sites.

[[Page 312]]



923.570-1  Applicability.

    (a) The policies, criteria, and procedure specified in 10 CFR part 
707, Workplace Substance Abuse Programs at DOE Sites, apply to contracts 
for work performed at sites owned or controlled by DOE and operated 
under the authority of the Atomic Energy Act of 1954, as amended, where 
such work:
    (1) Has a value of $25,000 or more, and;
    (2) Has been determined by DOE to involve:
    (i) Access to or handling of classified information or special 
nuclear materials;
    (ii) High risk of danger to life, the environment, public health and 
safety or national security; or
    (iii) The transportation of hazardous materials to or from a DOE 
site.
    (b) Except as otherwise provided for in this subpart, contracts 
subject to the requirements of 10 CFR part 707 and this subpart shall 
not be subject to FAR 23.5, Drug Free Workplace.
[57 FR 32676, July 22, 1992; 57 FR 41974, Sept. 14, 1992]



923.570-2  Solicitation provision and contract clause.

    (a) The contracting officer shall insert the provision at 48 CFR 
970.5204-57, Agreement Regarding Workplace Substance Abuse Programs at 
DOE Sites, in solicitations where the work to be performed by the 
contractor will occur on sites owned or controlled by DOE and operated 
under the authority of the Atomic Energy Act of 1954, as amended, as 
specified in 48 CFR 923.570-1, Applicability.
    (b) The contracting officer shall insert the clause at 970.5204-58, 
Workplace Substance Abuse Programs at DOE Sites, in contracts where the 
work to be performed by the contractor will occur on sites owned or 
controlled by DOE and operated under the authority of the Atomic Energy 
Act of 1954, as amended, as specified in 923.570-1, Applicability.
[57 FR 32676, July 22, 1992, as amended at 62 FR 42074, Aug. 5, 1997]



923.570-3  Suspension of payments, termination of contract, and debarment and suspension actions.

    (a) The contracting officer shall comply with the procedures of FAR 
23.506 regarding the suspension of contract payments, the termination of 
the contract for default, and the debarment and suspension of a 
contractor relative to failure to comply with 970.5204-58, Workplace 
Substance Abuse Programs at DOE Sites.
    (b) For purposes of 10 CFR part 707, the specific causes for 
suspension of contract payments, termination of the contract for 
default, and debarment and suspension of the contractor are:
    (1) The contractor fails to either comply with the requirements of 
10 CFR part 707 or perform in a manner consistent with its approved 
program;
    (2) The contractor has failed to comply with the terms of the 
provision at 48 CFR 970.5204-57; or
    (3) Such a number of contractor employees having been convicted of 
violations of criminal drug statutes for violations occurring on the 
DOE-owned or -controlled site, as to indicate that the contractor has 
failed to make a good faith effort to provide a drug free workplace.
[57 FR 32676, July 22, 1992, as amended at 62 FR 42074, Aug. 5, 1997]



  Subpart 923.70--Environmental, Conservation, and Occupational Safety 
                                Programs



923.7001  Nuclear safety.

    (a) The DOE regulates the nuclear safety of its major facilities 
under its own statutory authority derived from the Atomic Energy Act and 
other legislation. The DOE also regulates, under certain specific 
conditions, the use by its contractors of radioactive materials and 
ionizing radiation producing machines.
[49 FR 12003, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



923.7002  Contract clauses.

    (a) A decision to include or not include environmental, safety and 
health clauses in DOE contracts shall be made by the contracting officer 
in consultation with appropriate environmental,

[[Page 313]]

safety and health program management personnel.
    (b) When work is to be performed at a facility where the DOE will 
exercise its statutory authority to enforce occupational safety and 
health standards applicable to the working conditions of the contractor 
and subcontractor employees at such facility, the clause at 952.223-71 
shall be used in such contract or subcontract if conditions (b) (1) 
through (3), are satisfied:
    (1) DOE work is segregated from the contractor's or subcontractor's 
other work;
    (2) The operation is of sufficient size to support its own safety 
and health services; and
    (3) The facility is government-owned, or leased by or for the 
account of the government.
    (c) In facilities not meeting the requirements of 923.7002(b) above 
and which are a production or utilization facility where there is use or 
possession of source, special nuclear, or byproduct materials, DOE 
policy is not to enforce radiological safety and health standards 
pursuant to the contract or subcontract but rather to rely upon Nuclear 
Regulatory Commission (NRC) licensing requirements (including agreements 
with states under section 274 of the Atomic Energy Act). Pursuant to 
this policy, neither the clause found at 952.223-71 nor 952.223-72 is to 
be incorporated in the contracts or subcontracts for work at such 
facilities. Notwithstanding this general policy with respect to 
facilities not meeting the requirements of paragraph (b) above, the 
Secretary or his designee may determine in special cases, that DOE needs 
to enforce radiological safety and health standards pursuant to the 
contract or subcontract (see paragraph (d) below). When such a 
determination is made, the clause found at 952.223-72 shall be included 
in the contract or subcontract.
    (d) In facilities not meeting the requirements of either 923.7002(b) 
or 923.7002(c) of this section and where there is a machine capable of 
producing ionizing radiation, it is DOE policy not to regulate such 
activity where it is adequately regulated by a state or other Federal 
agency. In such cases, neither clause 952.223-71 nor 952.223-72 shall be 
incorporated in the contract. Where the contracting officer, with 
appropriate environmental, safety and health advice determines that no 
state or other Federal agency exists to adequately regulate the 
operation and/or use of such machines, the clause found at 952.223-72 
shall be included in the contract. The Assistant Secretary for 
Environment, Safety and Health (or designee) shall be consulted to 
determine if a non-agreement (NRC) state or a facility located in a non-
agreement state has been reviewed by any other DOE office to establish 
that the state agency has the essential authority and resources for 
enforcing the radiation protection standards. This is to assure 
reasonable consistency in the assessment of radiation protection in non-
agreement states and subsequent use of 952.223-72.
    (e) In a situation where the contractor or subcontractor is 
performing DOE work at more than one location, inclusion of either, or 
both, 952.223-71 and 952.223-72 may be appropriate. In such cases, the 
contract or subcontract must include language to specify the extent of 
applicability of each clause used. For example, with a parenthetical: 
(Applicable only to work performed at a contractor site which has 
952.223-71 or 952.223-72 clause in its contract or subcontract).
[49 FR 12003, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994; 62 
FR 2312, Jan. 16, 1997]



PART 925--FOREIGN ACQUISITION--Table of Contents




                Subpart 925.1--Buy American Act--Supplies

Sec.
925.102  Policy.
925.105  Evaluating offers.
925.108  Excepted articles, materials, and supplies.

         Subpart 925.2--Buy American Act--Construction Materials

925.202  Policy.
925.204  Violations.

        Subpart 925.7--Restrictions on Certain Foreign Purchases

925.702  Restrictions.

[[Page 314]]

          Subpart 925.9--Additional Foreign Acquisition Clauses

925.901  Omission of the audit clause.

        Subpart 925.70--Acquisition of Nuclear Hot Cell Services

925.7000  Scope of subpart.
925.7001  Definitions.
925.7002  Policy.
925.7003  Requirements.
925.7004  Contract clause.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12003, Mar. 28, 1984, unless otherwise noted.



                Subpart 925.1--Buy American Act--Supplies



925.102  Policy

    (b) Contracting officers may make the determination required by FAR 
25.102(a), provided such determination is factually supported in 
writing. If the contract is estimated to exceed $1 million, the Head of 
the Contracting Activity shall approve the determination.
[49 FR 12003, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984]



925.105  Evaluating offers.

    (c) Proposed awards shall be submitted (in triplicate) through the 
Procurement Executive, to the Head of the Agency for decisions required 
by FAR 25.105(c).



925.108  Excepted articles, materials, and supplies.

    (b) Suggestions for changes and additions to the (FAR) 48 CFR 
25.108(d)(1) list, with appropriate justifications, shall be submitted 
to the Procurement Executive.
[49 FR 12003, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



         Subpart 925.2--Buy American Act--Construction Materials



925.202  Policy.

    (b) Contracting officers may make the determination required by FAR 
25.202(a)(3). If the cost of the materials is expected to exceed 
$100,000, the Head of the Contracting Activity shall approve the 
determination.



925.204  Violations.

    Contracting officers shall make a complete written report (in 
triplicate) to the Secretary through the Procurement Executive of each 
violation of the Buy American Act--Construction Materials clause at 
52.225-5.
[49 FR 12003, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



        Subpart 925.7--Restrictions on Certain Foreign Purchases



925.702  Restrictions.

    No contract may be awarded to a company owned by an entity 
controlled by a foreign government if performance of the contract will 
require access to proscribed information. See 904.71 for additional 
guidance.
[58 FR 59684, Nov. 10, 1993]



          Subpart 925.9--Additional Foreign Acquisition Clauses



925.901  Omission of the audit clause.

    (c) Conditions for omission.
    Any proposed determinations and any reports mentioned at (FAR) 48 
CFR 25.901 shall be forwarded to the Director, Office of Clearance and 
Support, within the Headquarters procurement organization.
[59 FR 9106, Feb. 25, 1994, as amended at 61 FR 21977, May 13, 1996]



        Subpart 925.70--Acquisition of Nuclear Hot Cell Services

    Source:  58 FR 8910, Feb. 18, 1993, unless otherwise noted.



925.7000  Scope of subpart.

    This subpart prescribes policies for selection for contract award of 
nuclear hot cell services when one of the competitors is a foreign 
company. This subpart does not apply to the acquisition and use of 
nuclear hot cell facilities on-site at a DOE-owned or -leased facility.



925.7001  Definitions.

    Costs related to the decommissioning of nuclear facilities, as used 
in this subpart, means any cost associated with

[[Page 315]]

the compliance with regulatory requirements governing the 
decommissioning of nuclear facilities licensed by the Nuclear Regulatory 
Commission. Such costs for foreign facilities and for Department of 
Energy facilities are costs of decommissioning associated with the 
compliance with foreign regulatory requirements or the Department's own 
requirements.
    Costs related to the storage and disposal of nuclear waste, as used 
in this subpart, means any costs, whether required by regulation or 
incurred as a matter of prudent business practice, associated with the 
storage or disposal of nuclear waste.
    Foreign company, as used in this subpart, means a company which 
offers to perform nuclear hot cell services at a facility which is not 
subject to the laws and regulations of the United States, its agencies, 
and its political subdivisions.
    Nuclear hot cell services, as used in this subpart, means services 
related to the examination of, or performance of various operations on, 
nuclear fuel rods, control assemblies, or other components that are 
emitting large quantities of ionizing radiation, after discharge from 
nuclear reactors, which are performed in specialized facilities located 
away from commercial nuclear power plants, generally referred to in the 
industry as ``hot cells.''
    Nuclear waste, as used in this subpart, means any radioactive waste 
material subject to regulation by the Nuclear Regulatory Commission or 
the Department of Energy, or in the case of foreign offers, by 
comparable foreign organizations.
    United States company, as used in this subpart, means a company 
which offers to perform nuclear hot cell services at a facility subject 
to the laws and regulations of the United States, its agencies, and its 
political subdivisions.



925.7002  Policy.

    In selecting offer(s) for award of contracts for nuclear hot cell 
services, costs related to the decommissioning of nuclear facilities and 
storage and disposal of nuclear waste are to be considered in a way 
which affords United States and foreign companies an equal competition 
in accordance with 925.7003. Upon determining that no offer from a 
foreign firm has a reasonable chance of being selected for award, the 
requirements of this subpart will not apply.



925.7003  Requirements.

    (a) For the acquisition of nuclear hot cell services under the 
conditions in paragraph (b) of this section, the selection official in 
evaluating competitive offers for selection purposes only shall:
    (1) Consider neither costs related to the decommissioning of nuclear 
waste facilities nor costs related to the storage and disposal of 
nuclear waste, or
    (2) Add these costs to offers of foreign companies.
    (b) The requirements of this section apply under the following 
circumstances:
    (1) One or more of the offers is submitted by a United States 
company and includes costs related to the decommissioning of nuclear 
facilities and costs related to the storage and disposal of nuclear 
waste because it is subject to such costs; and
    (2) One or more of the offers is submitted by a foreign company and 
does not include these types of costs. (A foreign company might not be 
subject to such costs or might not have to include these types of costs 
in its offer if the firm is subsidized in decommissioning activity or 
storage and disposal of nuclear waste, or a foreign government is 
performing the activities below the actual cost of the activity.)



925.7004  Contract clause.

    The contracting officer shall insert the clause at 952.225-70, 
Subcontracting for Nuclear Hot Cell Services, in solicitations and 
contracts involving nuclear hot cell services. This clause does not flow 
down to second-tier subcontracts.



PART 926--OTHER SOCIOECONOMIC PROGRAMS--Table of Contents




Subpart 926.70--Implementation of Section 3021 of the Energy Policy Act 
                                 of 1992

Sec.
926.7001  Policy.
926.7002  Responsibilities.
926.7003  Review of the procurement request.
926.7004  Size standard for Energy Policy Act procurements.

[[Page 316]]

926.7005  Preferences under the Energy Policy Act.
926.7006  Goal measurement and reporting requirements.
926.7007  Solicitation provisions and contract clauses.

 Subpart 926.71--Implementation of Section 3161 of the National Defense 
                 Authorization Act for Fiscal Year 1993

926.7101  Policy.
926.7102  Definition.
926.7103  Requirements.
926.7104  Contract Clause.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  60 FR 22300, May 5, 1995, unless otherwise noted.



Subpart 926.70--Implementation of Section 3021 of the Energy Policy Act 
                                 of 1992



926.7001  Policy.

    (a) Section 3021(a) of the Energy Policy Act of 1992 (Pub. L. 102-
486) specifies that the Department of Energy shall, to the extent 
practicable, provide that not less than 10 percent of the total combined 
amounts obligated for competitively awarded contracts and subcontracts 
under the Energy Policy Act be expended with--
    (1) Small business concerns controlled by socially and economically 
disadvantaged individuals or by women;
    (2) Historically Black colleges and universities; or
    (3) Colleges and universities having a student body in which more 
than 20 percent of the students are Hispanic Americans or Native 
Americans.
    (b) These three groups are collectively referred to in this section 
as ``Energy Policy Act target groups.''
    (c) Awards of Energy Policy Act procurements should be in the 
following descending order of preference:
    (1) Competitive awards pursuant to a set-aside for small 
disadvantaged business;
    (2) Competitive awards to small businesses owned and controlled by 
socially and economically disadvantaged individuals and by women for 
Energy Policy Act requirements under the Small Business Administration's 
section 8(a) program; and
    (3) Competitive awards that provide an evaluation preference in 
accordance with 926.7006 to offerors from the Energy Policy Act target 
groups.
    (d) The DOE implementation of Section 3021 requirements with regard 
to the award of subcontracts under Energy Policy Act procurements is 
discussed at 926.7006.
    (e) Competitive procedures, for purposes of Energy Policy Act 
implementation, consist of awards under set-asides to small 
disadvantaged business and firms certified as 8(a) Small Business 
Administration and competitive procedures in accordance with (FAR) 48 
CFR 15.6 and (DEAR) 48 CFR 915.6.



926.7002  Responsibilities.

    Offices initiating procurement requests have primary responsibility 
to identify potential contract requirements falling within the scope of 
section 3021 of the Energy Policy Act. Identification shall occur at the 
earliest possible point in time in the acquisition cycle, but not later 
than the submission of the procurement request to the contracting 
officer. For purposes of Section 3021, a contract requirement is any 
award that directly satisfies an Energy Policy Act program or 
requirement.



926.7003  Review of the procurement request.

    Any Energy Policy Act procurement, including basic research 
contracts with educational institutions, shall be reviewed in accordance 
with the Small Business and 8(a) Program Review Procedures in order to 
ensure that full consideration is given to the potential for making 
Energy Policy Act awards.
[60 FR 22300, May 5, 1995, as amended at 61 FR 21977, May 13, 1996]



926.7004  Size standard for Energy Policy Act procurements.

    The size standard for Energy Policy Act engineering services 
procurements (SIC 8711) shall be the size standard specified for 
military and aerospace equipment and military weapons.

[[Page 317]]



926.7005  Preferences under the Energy Policy Act.

    (a) Prime contracts. Solicitations for all competitive Energy Policy 
Act procurements not for 8(a) firms and in excess of the simplified 
acquisition threshold shall provide for an evaluation preference for 
offers received from entities from among the Energy Policy Act target 
groups. The evaluation criteria shall provide that in instances in which 
two or more proposals being considered for final selection are ranked as 
essentially equal after consideration of all technical and cost 
evaluation factors, and if one of these proposals is from an offeror 
from among an Energy Policy Act target group that offeror will be 
selected for award.
    (b) Subcontracts. (1) The contracting officer shall assure that all 
competitive Energy Policy Act solicitations over the simplified 
acquisition threshold contain:
    (i) A solicitation provision providing for consideration of the 
extent to which the offerors have provided for subcontracting 
opportunities to entities from among the Energy Policy Act target 
groups; and
    (ii) A clause providing for the maximum utilization of entities from 
among Energy Policy Act target groups in the performance of Energy 
Policy Act contracts.
    (2) In addition, the contracting officer shall assure that all 
competitive Energy Policy Act procurements expected to exceed $500,000 
($1,000,000 for construction) include a clause for reporting after award 
as part of the Small Business and Small Disadvantaged Business 
Subcontracting Plan process.



926.7006  Goal measurement and reporting requirements.

    (a) General. The following types of contract awards for Energy 
Policy Act procurements shall be counted toward achievement by DOE of 
the 10 percent goal:
    (1) Any award set-aside for small disadvantaged business;
    (2) Any competitive section 8(a) award;
    (3) Any competitive award to one of the three target groups under an 
unrestricted procurement;
    (4) Any award to one of the three target groups conducted under 
simplified acquisition procedures in excess of the micro-purchase 
threshold; and,
    (5) Any competitively awarded subcontract to one of the three target 
groups under a prime award.
    (b) Prime contract awards. Award values and dollars obligated under 
prime contracts and modifications to prime contracts for Energy Policy 
Act requirements shall be reported through the Department of Energy 
Procurement and Assistance Data System.
    (c) Subcontract awards. The contractor shall be required to report, 
on an annual Federal Government fiscal year basis, its progress against 
Section 3021 goals by providing the actual dollar value of subcontract 
payments and the relationship of those payments to the incurred contract 
cost. If the contract includes reporting requirements under (FAR) 48 CFR 
52.219-9, Small Business and Small Disadvantaged Business Subcontracting 
Plan, the contractor's progress against the Section 3021 goals shall be 
included as an addendum to Standard Form (SF) 294, Subcontracting Report 
for Individual Contracts, and/or SF 295, Summary Subcontract Report, as 
applicable, for the period that corresponds to the end of the Federal 
Government fiscal year.



926.7007  Solicitation provisions and contract clauses.

    (a) The contracting officer shall insert the provision at 952.226-
70, Subcontracting Goals under Section 3021(a) of the Energy Policy Act 
of 1992 (Pub. L. 102-486) (Energy Policy Act), in solicitations for 
Energy Policy Act procurements.
    (b) The contracting officer shall insert the clause at 952.226-71, 
Utilization of Energy Policy Act Target Entities, in contracts for the 
Energy Policy Act requirements with an award value in excess of the 
simplified acquisition threshold.
    (c) The contracting officer shall insert the clause at 952.226-72, 
Energy Policy Act Subcontracting Goals and Reporting Requirements, in 
contracts for Energy Policy Act requirements with an award value in 
excess of $500,000 ($1,000,000 in the case of construction).

[[Page 318]]

    (d) The contracting officer shall insert the provision at 48 CFR 
952.226-73, Energy Policy Act Target Group Representation, in 
solicitations for Energy Policy Act procurements.
    (e) The contracting officer shall insert the clause at (FAR) 48 CFR 
52.219-14, Limitation on Subcontracting, in contracts for Energy Policy 
Act requirements with an entity from among the Energy Policy Act target 
groups.
[60 FR 22300, May 5, 1995, as amended at 62 FR 42074, Aug. 5, 1997]



 Subpart 926.71--Implementation of Section 3161 of the National Defense 
                 Authorization Act for Fiscal Year 1993.

    Source: 62 FR 34861, June 27, 1997, unless otherwise noted.



926.7101  Policy.

    Consistent with the requirements of Section 3161(c)(2), 42 U.S.C. 
7474h(c)(2), in instances where DOE has determined that a change in 
workforce at a DOE Defense Nuclear Facility is necessary, the 
Department, to the extent practicable, is required to provide employees 
under Department of Energy contracts whose employment in positions at 
such a facility is terminated with a preference in any hiring of the 
Department. Consistent with published DOE guidance regarding Section 
3161, such preference in hiring extends to hiring by DOE contractors and 
subcontractors.



926.7102  Definition.

    Eligible employee means a current or former employee of a contractor 
or subcontractor employed at a DOE Defense Nuclear Facility--
    (1) Whose position of employment has been, or will be, involuntarily 
terminated (except if terminated for cause),
    (2) Who has met the eligibility criteria contained in Department of 
Energy guidance for contractor work force restructuring, as may be 
amended or supplemented from time to time, and
    (3) Who is qualified for a job vacancy with the Department or one of 
its contractors with respect to work under its contract with the 
Department at the time a position is available.



926.7103  Requirements.

    (a) Section 3161, 42 U.S.C. 7474h, confers a continuing right to a 
preference in hiring to an eligible employee of Department of Energy 
Defense Nuclear Facilities. This right to a preference in hiring 
includes employment opportunities of any Department of Energy 
contractor, regardless of the place of performance of the contract. 
Accordingly, eligible former employees of contractors and subcontractors 
employed at Department of Energy Defense Nuclear Facilities, to the 
extent practicable, shall be provided a hiring preference in employment 
opportunities of other Department of Energy contractors for work under 
their contracts.
    (b) The Office of Worker and Community Transition (WT) is 
responsible for establishing policies and procedures relating to the 
Department of Energy implementation of Section 3161. Contracting 
Officers, in concert with representatives of the field office 
responsible for implementation of Section 3161 at the Department of 
Energy Defense Nuclear Facility and local counsel, should consult with 
the Office of Worker and Community Transition to determine applicability 
of Section 3161 requirements, including hiring preference requirements, 
for displaced workers.



926.7104  Contract clause.

    The contracting officer shall insert the clause at 48 CFR (DEAR) 
952.226-74, Displaced Employee Hiring Preference, in contracts (except 
for contracts for commercial items, pursuant to 41 U.S.C. 403) which 
exceed $500,000 in value.

[[Page 319]]



             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS





PART 927--PATENTS, DATA, AND COPYRIGHTS--Table of Contents




                         Subpart 927.2--Patents

Sec.
927.200  Scope of subpart.
927.201  Authorization and consent.
927.201-1  General.
927.206  Refund of royalties.
927.206-1  General.
927.206-2  Clause for refund of royalties.
927.207  Classified contracts.
927.207-1  General.

         Subpart 927.3--Patent Rights Under Government Contracts

927.300  General.
927.302  Policy.
927.303  Contract clauses.
927.304  Procedures.
927.370  Waiver of title to certain sensitive inventions.

              Subpart 927.4--Technical Data and Copyrights

927.400  Scope of subpart.
927.401  Definitions.
927.402  Acquisition and use of technical data.
927.402-1  General.
927.402-2  Policy.
927.402-3  Procedures (supply, research, development, or demonstration 
          contracts).
927.403  Negotiations and deviations.

           Subpart 927.70--Disclosure of Proposal Information

927.7000  Disclosure outside Government.
927.7001  Proposal information.
927.7002  Treatment of proposal information.
927.7003  Handling notice.
927.7004  Identification of proprietary data in proposals.
927.7004-1  Solicited proposals.
927.7004-2  Solicitations.
927.7004-3  Unsolicited proposals.
927.7005  Required notice of right to request patent waiver.

    Authority:  Sec. 644 of the Department of Energy Organization Act, 
Pub. L. 95-91 (42 U.S.C. 7254); Sec. 148 of the Atomic Energy Act of 
1954, as amended (42 U.S.C. 2168); Federal Nonnuclear Energy Research 
and Development Act of 1974, Sec. 9, (42 U.S.C. 5908); Atomic Energy Act 
of 1954, as amended, Sec. 152, (42 U.S.C. 2182); Department of Energy 
National Security and Military Applications of Nuclear Energy 
Authorization Act of 1987, as amended, Sec. 3131(a), (42 U.S.C. 7261a.)

    Source:  49 FR 12004, Mar. 28, 1984, unless otherwise noted.



                         Subpart 927.2--Patents

    Source:  60 FR 11815, Mar. 2, 1995, unless otherwise noted.



927.200  Scope of subpart.

    When consulting 48 CFR part 27, subpart 27.2 of the FAR, consider 
``research, development, and demonstration'' to replace the phrase 
``research and development'' or ``R&D,'' for the purposes of DOE 
actions.



927.201  Authorization and consent.



927.201-1  General.

    In certain contracting situations, such as those involving research, 
development, or demonstration projects, consideration should be given to 
the impact of third party-owned patents covering technology that may be 
incorporated in the project which patents may ultimately affect 
widespread commercial use of the project results. In such situations, 
Patent Counsel shall be consulted to determine what modifications, if 
any, are to be made to the utilization of the Authorization and Consent 
and Patent Indemnity provisions or what other action might be deemed 
appropriate.



927.206  Refund of royalties.



927.206-1  General.

    The clause at 952.227-9, Refund of Royalties, obligates the 
contractor to inform DOE of the payment of royalties pertaining to the 
use of intellectual property, either patent or data related, in the 
performance of the contract. This information may result in 
identification of instances in which the Government already has a 
license for itself or others acting in its behalf or the right to 
sublicense others. Also, there may be pending antitrust actions or 
challenges to the validity of a patent or the proprietary nature of the 
data, or the contractor may be able to

[[Page 320]]

gain unrestricted access to the same data through other sources. In such 
situations the contractor may avoid the payment of a royalty in its 
entirety or may be charged a reduced royalty.



927.206-2  Clause for refund of royalties.

    The contracting officer shall insert the clause at 952.227-9, Refund 
of Royalties, in solicitations and contracts for experimental, research, 
developmental, or demonstration work or other solicitations and 
contracts in which the contracting officer believes royalties will have 
to be paid by the contractor or a subcontractor of any tier.



927.207  Classified contracts.



927.207-1  General.

    Unauthorized disclosure of classified subject matter, whether in a 
patent application or resulting from the issuance of a patent, may be a 
violation of the Atomic Energy Act of 1954, as amended, other laws 
relating to espionage and national security, and provisions of the 
proposed contract pertaining to disclosure of information.



         Subpart 927.3--Patent Rights Under Government Contracts



927.300  General.

    (a) One of the primary missions of the Department of Energy is the 
use of its procurement process to ensure the conduct of research, 
development, and demonstration leading to the ultimate commercialization 
of efficient sources of energy. To accomplish its mission, DOE must work 
in cooperation with industry in the development of new energy sources 
and in achieving the ultimate goal of widespread commercial use of those 
energy sources. To this end, Congress has provided DOE with the 
authority to invoke an array of incentives to secure the 
commercialization of new technologies developed for DOE. One such 
important incentive is provided by the patent system.
    (b) Pursuant to 42 U.S.C. 2182 and 42 U.S.C. 5908, DOE takes title 
to all inventions conceived or first actually reduced to practice in the 
course of or under contracts with large, for-profit companies, foreign 
organizations, and others not beneficiaries of Pub. L. 96-517. 
Regulations dealing with Department's authority to waive its title to 
subject inventions, including the relevant statutory objectives, exist 
at 41 CFR 9-9.109. Pursuant to that section, DOE may waive the 
Government's patent rights in appropriate situations at the time of 
contracting to encourage industrial participation, foster commercial 
utilization and competition, and make the benefits of DOE activities 
widely available to the public. In addition to considering the waiver of 
patent rights at the time of contracting, DOE will also consider the 
incentive of a waiver of patent rights upon the reporting of an 
identified invention when requested by such entities or by the employee-
inventor with the permission of the contractor. These requests can be 
made whether or not a waiver request was made at the time of 
contracting. Waivers for identified inventions will be granted where it 
is determined that the patent waiver will be a meaningful incentive to 
achieving the development and ultimate commercial utilization of 
inventions. Where DOE grants a waiver of the Government's patent rights, 
either at the time of contracting or after an invention is made, certain 
minimum rights and obligations will be required by DOE to protect the 
public interest.
    (c) Another major DOE mission is to manage the nation's nuclear 
weapons and other classified programs, where research and development 
procurements are directed toward processes and equipment not available 
to the public. To accomplish DOE programs for bringing private industry 
into these and other special programs to the maximum extent permitted by 
national security and policy considerations, it is desirable that the 
technology developed in these programs be made available on a selected 
basis for use in the particular fields of interest and under controlled 
conditions by properly cleared industrial and scientific research 
institutions. To ensure such availability and control, the grant of 
waivers in these programs may necessarily be more limited, either by the 
imposition of field of use restrictions

[[Page 321]]

or national security measures, than in other DOE programs.
[60 FR 11815, Mar. 2, 1995]



927.302  Policy.

    (a) Except for contracts with organizations that are beneficiaries 
of Public Law 96-517, the United States, as represented by DOE, shall 
normally acquire title in and to any invention or discovery conceived or 
first actually reduced to practice in the course of or under the 
contract, allowing the contractor to retain a nonexclusive, revocable, 
paid-up license in the invention and the right to request permission to 
file an application for a patent and retain title to any ensuing patent 
in any foreign country in which DOE does not elect to secure patent 
rights. DOE may approve the request if it determines that such approval 
would be in the national interest. The contractor's nonexclusive license 
may be revoked or modified by DOE only to the extent necessary to 
achieve expeditious practical application of the invention pursuant to 
any application for and the grant of an exclusive license in the 
invention to another party.
    (b) In contracts having as a purpose the conduct of research, 
development, or demonstration work and in certain other contracts, DOE 
may need to require those contractors that are not the beneficiaries of 
Public Law 96-517 to license background patents to ensure reasonable 
public availability and accessibility necessary to practice the subject 
of the contract in the fields of technology specifically contemplated in 
the contract effort. That need may arise where the contractor is not 
attempting to take the technology resulting from the contract to the 
commercial marketplace, or is not meeting market demands. The need for 
background patent rights and the particular rights that should be 
obtained for either the Government or the public will depend upon the 
type, purpose, and scope of the contract effort, impact on the DOE 
program, and the cost to the Government of obtaining such rights.
    (c) Provisions to deal specifically with DOE background patent 
rights are contained in paragraph (k) of the clause at 952.227-13. That 
paragraph may be modified with the concurrence of Patent Counsel in 
order to reflect the equities of the parties in particular contracting 
situations. Paragraph (k) should normally be deleted for contracts with 
an estimated cost and fee or price of $250,000 or less and may not be 
appropriate for certain types of study contracts; for planning 
contracts; for contracts with educational institutions; for contracts 
for specialized equipment for in-house Government use, not involving use 
by the public; and for contracts the work products of which will not be 
the subject of future procurements by the Government or its contractors.
    (d) The Assistant General Counsel for Technology Transfer and 
Intellectual Property shall:
    (1) Make the determination that whether reported inventions are 
subject inventions under the patent rights clause of the contract;
    (2) Determine whether and where patent protection will be obtained 
on inventions;
    (3) Represent DOE before domestic and foreign patent offices;
    (4) Accept assignments and instruments confirmatory of the 
Government's rights to inventions; and
    (5) Represent DOE in patent, technical data, and copyright matters 
not specifically reserved to the Head of the Agency or designee.
[60 FR 11816, Mar. 2, 1995]



927.303  Contract clauses.

    (a) In solicitations and contracts for experimental, research, 
developmental, or demonstration work (but see (FAR) 48 CFR 27.304-3 
regarding contracts for construction work or architect-engineer 
services), the contracting officer shall include the clause:
    (1) At 952.227-13, Patent Rights Acquisition by the Government, in 
all such contracts other than those described in paragraphs (a)(2) and 
(a)(3) of this section;
    (2) At 952.227-11, Patent Rights by the Contractor (Short Form), in 
contracts in which the contractor is a domestic small business or 
nonprofit organization as defined at (FAR) 48 CFR 27.301, except where 
the work of the contract is subject to an Exceptional Circumstances 
Determination by DOE; and

[[Page 322]]

    (3) At 970.5204-71 or 970.5204-72, as discussed in 970.27, Patent, 
Data, and Copyrights, in contracts for the management and operation of 
DOE laboratories and production facilities.
    (b) DOE shall not use the clause at (FAR) 48 CFR 52.227-12 except in 
situations where patent counsel grants a request for advance waiver and 
supplies the contracting officer with that clause with appropriate 
modifications. Otherwise, in instances in which DOE grants an advance 
waiver or waives its rights in an identified invention, contracting 
officers shall consult with patent counsel for the appropriate clause.
[60 FR 11816, Mar. 2, 1995]



927.304  Procedures.

    Where the contract contains the clause at 952.227-11 and the 
contractor does not elect to retain title to a subject invention, DOE 
may consider and, after consultation with the contractor, grant requests 
for retention of rights by the inventor subject to the provisions of 35 
U.S.C. 200 et seq. This statement is in lieu of (FAR) 48 CFR 27.304-
1(c).
[60 FR 11816, Mar. 2, 1995]



927.370  Waiver of title to certain sensitive inventions.

    (a) Whenever any contractor makes an invention or discovery to which 
the title vests in the Department of Energy pursuant to exercise of 
section 202(a) (ii) or (iv) of title 35, United States Code, or pursuant 
to section 152 of the Atomic Energy Act of 1954 (42 U.S.C. 2182) or 
section 9 of the Federal Nonnuclear Energy Research and Development Act 
of 1974 (42 U.S.C. 5908), in the course of or under any Government 
contract or subcontract of the Naval Nuclear Propulsion Program or the 
nuclear weapons programs or other atomic energy defense activities of 
the Department of Energy, and the contractor requests waiver of any or 
all of the Government's property rights, the Secretary of Energy may 
decide to waive the Government's rights and assign the rights in such 
invention or discovery.
    (b) In making a decision under this section, the Secretary or his 
designee shall:
    (1) Apply the stated general objectives for patent waivers under 
sec. 92.300(a) of this subpart;
    (2) Take into account the specific considerations applicable to 
advance waivers and identified invention waivers, respectively, under 
sec. 927.300(a) of this subpart;
    (3) Consider whether national security will be compromised;
    (4) Consider whether sensitive technical information (whether 
classified or unclassified) under the Naval Nuclear Propulsion Program 
or the nuclear weapons programs or other atomic energy defense 
activities of the Department of Energy for which dissemination is 
controlled under Federal statutes and regulations will be released to 
unauthorized persons;
    (5) Consider whether an organizational conflict of interest 
contemplated by Federal statutes and regulations will result; and
    (6) Consider whether waiving such rights will adversely affect the 
operation of the Naval Nuclear Propulsion Program or the nuclear weapons 
programs or other atomic energy defense activities of the Department of 
Energy.
    (c) A decision under this section shall be made within 150 days 
after the date on which a complete request for waiver, as described by 
paragraph (d) of this section, has been submitted to the Patent Counsel 
by the contractor.
    (d) In addition to the requirements for content which apply 
generally to all waiver requests under sec. 927.300(a) of this subpart, 
a requestor must include a full and detailed statement of facts, to the 
extent known by or available to the requestor, directed to the 
considerations set forth in paragraphs (b)(3) through (6) of this 
section, as applicable. To be considered complete, a waiver request must 
contain sufficient information, in addition to the content requirements 
under sec. 927.300(a) of this subpart, to allow the Secretary or his 
designee to make a decision under this section. Such information shall 
include, at a minimum, for advance waiver requests:
    (1) An identification of all of the petitioner's contractual 
arrangements involving the Government (including contracts, 
subcontracts, grants, or

[[Page 323]]

other arrangements) in which the technology involved in the contract was 
developed or used and any other funding of the technology by the 
Government, whether direct or indirect, involving any other party, of 
which the petitioner is aware;
    (2) A description of the petitioner's past, current, and future 
private investment in and development of the technology which is the 
subject of the contract. This includes expenditures not reimbursed by 
the Government on research and development which will directly benefit 
the work to be performed under the instant contract, the amount and 
percentage of contract costs to be shared by the petitioner, the out-of-
pocket costs of facilities or equipment to be made available by the 
petitioner for performance of the contract work which are not charged 
directly or indirectly to the Government under contract, and the 
contractor's plans and intentions to further develop and commercialize 
the technology at private expense;
    (3) A description of competitive technologies or other factors which 
would ameliorate any anticompetitive effect of granting the waiver.
    (4) Identification of whether the contract pertains to work that is 
classified, or sensitive, i.e., unclassified but controlled pursuant to 
section 148 of the Atomic Energy Action of 1954, as amended (42 U.S.C. 
2168) (1982), or subject to export control under Chapter 17 of the 
Military Critical Technology List (MCTL) contained in Department of 
Defense Directive 5230.25, including identification of all principal 
uses of the subject matter of the contract, whether inside or outside 
the contractor program, and an indication of whether any such uses 
involve classified or sensitive technologies.
    (5) Identification of all DOE and DOD programs and projects in the 
same general technology as the contract for which the petitioner intends 
to be providing program planning advice or has provided program planning 
advice within the last three years.
    (e) For identified invention requests, such requests shall include 
at a minimum:
    (1) A brief description of the intentions of the petitioner (or its 
present or intended licensee) to commercialize the invention. This 
description should include: (i) estimated expenditures, (ii) anticipated 
steps, (iii) the associated time periods to bring the invention to 
commercialization, and (iv) a statement that petitioner (or its present 
or intended licensee) has the capability to carry out its stated 
intentions.
    (2) A description of any continuing Government funding of the 
development of the invention (including investigation of materials or 
processes for use therewith), from whatever Government source, whether 
direct or indirect, and, to the extent known by the petitioner, any 
anticipated future Government funding to further develop the invention.
    (3) A description of competitive technologies or other factors which 
would ameliorate any anticompetitive effects of granting the waiver.
    (4) A statement that petitioner will reimburse the Department of 
Energy for any and all costs and fees incurred by the Department in the 
preparation and prosecution of the patent applications covering the 
invention that is the subject of the waiver petition.
    (5) Where applicable, a statement of reasons why the petition was 
not timely filed in accordance with the applicable patent rights clause 
of the contract, or why a request for an extension of time to file the 
petition was not filed in a timely manner.
    (6) Identification of whether the invention pertains to work that is 
classified, or sensitive, i.e., unclassified but controlled pursuant to 
section 148 of the Atomic Energy Action of 1954, as amended, (42 U.S.C. 
2168) (1982), or subject to export control under Chapter 17 of the 
Military Critical Technology List (MCTL) contained in Department of 
Defense Directive 5230.25, including identification of all principal 
uses of the invention inside or outside the contractor program, and an 
indication of whether any such uses involve classified or sensitive 
technologies.
    (7) Identification of all DOE and DOD programs and projects in the 
same general technology as the invention for which the petitioner 
intends to be providing program planning advice or has provided program 
planning advice within the last three years.

[[Page 324]]

    (8) A statement of whether a classification review of the invention 
disclosure, any resulting patent application(s), and/or any reports and 
other documents disclosing a substantial portion of the invention has 
been made, together with any determinations on the existence of 
classified or sensitive information in either the invention disclosure, 
the patent application(s), or reports or other documents disclosing a 
substantial portion of the invention; and
    (9) Identification of any and all proposals, work for others 
activities, or other arrangements submitted by the petitioner, DOE, or a 
third party, of which petitioner is aware, which may involve further 
funding of the work on the invention at either the contractor facility 
where the invention arose or another facility owned by the Government.
    (f) Patent Counsel will notify the petitioner promptly if the waiver 
request is found not to be a complete request and, in that event, will 
provide the petitioner with a reasonable period, not to exceed 60 days, 
to correct any such incompleteness. If petitioner does not respond 
within the allotted time period, the waiver request will be considered 
to be withdrawn. If petitioner responds within the allotted time period, 
but the submittal is still deemed incomplete or insufficient, the waiver 
request may be denied.
    (g) For waiver requests as described in this section, waiver 
decisions shall be made within 150 days after the date on which a 
complete request for waiver of such rights, as specified herein, has 
been submitted by the petitioner to the DOE Patent Counsel. If the 
original waiver request does not result in a communication from DOE 
Patent Counsel indicating that the request is incomplete, the 150-day 
period for decision commences on the date of receipt of the waiver 
petition. If the original waiver request results in a communication from 
DOE Patent Counsel indicating that the request is incomplete, the 150-
day period for decision commences on the date on which supplementary 
information is received by Patent Counsel sufficient to make the waiver 
request complete. For advance waiver requests, if petitioner is not 
notified that the request is incomplete, the 150-day period for decision 
commences on the date of receipt of the petition, or on the date on 
which negotiation of contract terms is completed, whichever is later.
    (h) Failure of DOE to make a patent waiver decision within the 
prescribed 150-day period shall in no way be construed as a grant of the 
waiver.
[53 FR 51278, Dec. 21, 1988]



              Subpart 927.4--Technical Data and Copyrights



927.400  Scope of subpart.

    This subpart sets forth DOE's policy, procedures, and instructions 
for contract clauses with respect to the acquisition and use of 
technical data and copyrights in contracts or subcontracts entered into, 
with or for the benefit of the Government.



927.401  Definitions.

    Technical data means for the purpose of this subpart, recorded 
information, regardless of form or characteristic, of a scientific or 
technical nature. It may, for example, document research, experimental, 
developmental, demonstration, or engineering work or be usable or used 
to define a design or process or to procure, produce, support, maintain, 
or operate material. The data may be graphic or pictorial delineations 
in media such as drawings or photographs, text in specifications or 
related performance or design type documents, or computer software 
(including computer programs, computer software data bases, and computer 
software documentation). Examples of technical data include research and 
engineering data, engineering drawings and associated lists, 
specifications, standards, process sheets, manuals, technical reports, 
catalog item identification, and related information. Technical data, as 
used in this subpart, do not include financial reports, cost analyses, 
and other information incidental to contract administration.
    Proprietary data means for the purpose of this subpart, technical 
data which embody trade secrets developed

[[Page 325]]

at private expense, such as design procedures or techniques, chemical 
composition of materials, or manufacturing methods, processes, or 
treatments, including minor modifications thereof, provided that such 
data:
    (1) Are not generally known or available from other sources without 
obligation concerning their confidentiality;
    (2) Have not been made available by the owner to others without 
obligation concerning their confidentiality; and
    (3) Are not already available to the Government without obligation 
concerning their confidentiality.
    Contract data means for the purpose of this subpart, technical data 
first produced in the performance of the contract, technical data which 
are specified to be delivered under the contract, technical data that 
may be called for under the Additional Technical Data Requirements 
clause of the contract, if any, or technical data actually delivered in 
connection with the contract.
    Unlimited rights means for the purpose of this subpart, rights to 
use, duplicate or disclose technical data, in whole or in part, in any 
manner and for any purpose whatsoever, and to permit others to do so.



927.402  Acquisition and use of technical data.



927.402-1  General.

    (a) The provisions herein pertain to research, development, 
demonstration and supply contracts. Special considerations for contracts 
for the operation, design, or construction of Government-owned 
facilities are covered by subpart 970.27. Under DOE's broad charter to 
perform research, development, and demonstration work, in both nuclear 
and nonnuclear fields, and to meet the objectives stated in 927.402-2, 
DOE has extensive needs for technical data. The satisfaction of these 
needs and the achievement of DOE's objectives through a sound data 
policy are found in the balancing of the needs and equities of the 
Government, its contractors, and the general public.
    (b) It is important to keep a clear distinction between contract 
requirements for the delivery of technical data on the one hand, and 
rights in technical data on the other. The legal rights which the 
Government acquires in technical data in DOE contracts (other than 
``facilities'' contracts) are set forth in the Rights in Technical Data 
(long form) clause of 952.227-75. However, this clause does not obtain 
for the Government the delivery of any data whatsoever. Rather, known 
requirements for the technical data to be delivered by the contractor 
shall be set forth as part of the contract (e.g. in the statement of 
work). The Additional Technical Data Requirements clause at 952.227-73 
may be used along with the clause at 952.227-75 to enable the 
contracting officer to require the contractor to furnish additional 
technical data, the requirement for which was not known at the time of 
contracting. There is, however, a built-in limitation on the kind of 
technical data which a contractor may be required to deliver under 
either the contract statement of work or the Additional Technical Data 
Requirements clause. This limitation is found in the withholding 
provision of paragraph (e) of the Rights in Technical Data (long form) 
clause of 952.227-75 which provides that the contractor need not furnish 
``proprietary data.'' It is specifically intended that the contractor 
may withhold ``proprietary data'' even though a requirement for 
technical data specified in the statement of work or called for pursuant 
to the Additional Technical Data Requirements clause would seemingly 
require the furnishing of proprietary data. This withholding of 
proprietary data is the primary means by which the contractor may 
protect its proprietary position.
    (c) There are, however, two situations where the Government, or its 
representative, may need to have limited access to a contractor's 
proprietary data.
    (1) First, paragraph (f) of the Rights in Technical Data (long form) 
clause gives the contracting officer's representatives the limited right 
to inspect at the contractor's facility the contractor's proprietary 
data which were withheld from delivery under paragraph (e) of the clause 
for the purpose of verifying that such data were properly withheld or to 
evaluate work

[[Page 326]]

performance. In carrying out the inspection, normally the contracting 
officer's representative is a DOE employee although he may be an 
employee of a DOE contractor acting under an agreement to treat in 
confidence the proprietary data to be inspected. However, where the 
contractor whose data are to be inspected demonstrates that there would 
be a possible conflict of interest if the inspection were made by such a 
contractor employee, the contracting officer's representative may be 
limited to a DOE employee. Paragraph (f) has a built-in exclusion from 
these inspection rights for ``specific items of proprietary data'' when 
they are so specified in the contract schedule. Such exclusions limit 
even DOE's minimum rights of evaluating contract work performance and 
verifying that technical data withheld by the contractor is proprietary 
in fact. Such exclusions should be sparingly used, and only in 
situations where program personnel stipulate to the fact that DOE has no 
need for access to the specified items to be excluded from paragraph 
(f), i.e., that the nondisclosure and nonaccessibility will not 
adversely affect the DOE program involved. It should also be noted that 
paragraph (f) permits exclusion of ``specific items'' of proprietary 
data and, accordingly, should not be used to exclude classes of 
technical data or all technical data pertaining to specific items or 
processes or classes of items or processes.
    (2) The second situation, where the Government may have limited 
access to a contractor's proprietary data, is provided in optional 
paragraph (g) of the Rights in Technical Data (long form) clause at 
952.227-75 Alternate I. When used, optional paragraph (g) provides the 
Government the right to require the contractor to furnish with limited 
rights the proprietary data previously withheld under paragraph (e). In 
this situation, the limited rights in proprietary data and the 
Government's obligation for limited use and disclosure of such data as 
set forth in the Rights in Technical Data (long form) clause provides 
the means by which the contractor protects its proprietary position. 
Paragraph (g) will be used only where it is determined by DOE that for 
programmatic reasons there is a need for the delivery of proprietary 
data to the Government. Where proprietary data is to be delivered under 
paragraph (g) and subparagraph (a) or (b) of the limited rights legend 
is to be applied to the data, the contractor may, if he can show the 
possibility of a conflict of interest regarding disclosure of such data 
to other contractors, limit or modify subparagraph (a) or (b) as set 
forth in 927.402-3(e)(2), to exclude or include certain contractors.
    (d) The contractor licensing provisions of optional paragraph (h) at 
952.227-75 Alternate II of the Rights in Technical Data (long form) 
clause enable DOE to require limited licenses in proprietary contract 
data to be granted to the Government and responsible parties in certain 
circumstances. Such a license may parallel or supplement the license 
obtained in background patents under the provisions of paragraph (k) of 
the Patent Rights clause of 41 CFR 9-9.107-5(a). Paragraph (h) is 
normally to be included in contracts for research, development or 
demonstration where it is deemed by DOE that the limited license 
afforded therein is necessary to ensure widespread commercial use or 
practical utilization of a subject of the contract. As explained in 
927.402-3(e)(3), paragraph (h) provides that upon request by DOE, the 
contractor will grant to the Government and responsible third parties a 
license in proprietary data only where such data in the form of results 
obtained by its use, i.e., essential equipment, articles, products, and 
the like which were the subject of the contract, are not otherwise 
available, or cannot be made available in a reasonable time as set forth 
in paragraph (h).
    (e)(1) It is the responsibility of prime contractors and higher tier 
subcontractors, in meeting their obligations with respect to contract 
data, to obtain from their subcontractors the rights in, access to, and 
delivery of such data on behalf of the Government. Accordingly, subject 
to the policy set forth in these regulations, and subject to the 
approval of the contracting officer where required, selection of 
appropriate technical data provisions for subcontracts is the 
responsibility of the prime contractor or higher-tier

[[Page 327]]

subcontractor. In many but not all instances, inclusion in a subcontract 
of the Rights in Technical Data (long form) clause of 952.227-75 will 
suffice to obtain for the benefit of the Government the rights in and, 
if appropriate, access to technical data. Access by DOE to technical 
data, i.e., the inspection rights afforded in paragraph (f) of the 
Rights in Technical Data (long form) clause at 952.227-75 normally 
should be obtained only in first-tier subcontracts having as a purpose 
the conduct of research, development, or demonstration work or the 
furnishing of supplies for which there are substantial technical data 
requirements as reflected in the prime contract. If a subcontractor 
refuses to accept technical data provisions affording rights in and 
access to technical data on behalf of the Government, the contractor 
shall so inform the Contracting Officer in writing and not proceed with 
the subcontract without written authorization of the Contracting 
Officer. In prime contracts (or higher-tier subcontracts) which contain 
the Additional Technical Data Requirements clause, it is the further 
responsibility of the contractor (or higher-tier subcontractor) to 
determine whether inclusion of such clause in a subcontract is required 
to satisfy technical data requirements of the prime contract (or higher-
tier subcontract).
    (2) As is the case for DOE in its determination of technical data 
requirements, the Additional Technical Data at 952.227-73 Requirements 
clause should not be used at any subcontracting tier where the technical 
data requirements are fully known, and normally the clause will be used 
only in subcontracts having as a purpose the conduct of research, 
development, or demonstration. Prime contractors and higher-tier 
subcontractors shall not use their power to award subcontracts as 
economic leverage to inequitably acquire rights in the subcontractor's 
proprietary data for their private use, and they shall not acquire 
rights on behalf of the Government to proprietary data for standard 
commercial items unless required by the prime contract.
    (f) Related to the acquisition and use of technical data are the 
contractor's rights in contract data as well as technical data furnished 
to the contractor by DOE or its contractors. These rights are set forth 
in paragraph (b)(2) of each Rights in Technical Data clause and provide 
that the contractor may, subject to patent, security and other 
provisions of the contract, use for its private purposes contract data 
it first produces in the performance of the contract, provided that the 
contractor has met its data requirements (e.g., delivery of data in form 
of progress or status reports specified to be delivered) as of the date 
of the private use of such data. It is not necessary that a final report 
be submitted in order to privately use data if all required progress and 
interim reports and other technical data then due have been delivered. 
Paragraph (b)(2) further provides that technical or other data received 
by the contractor in the performance of the contract must be held in 
confidence by the contractor in accordance with restrictions 
accompanying the data.
    (g) An additional clause described further at 927.402-3(f), the text 
of which is found at 952.227-76 entitled Rights in Data--Special Works, 
is to be used in place of or in addition to the Rights in Technical Data 
(long form) clause in contracts where a purpose of the contract is the 
production of copyrightable material, a substantial portion of which is 
to be first produced in the performance of the contract, such as motion 
pictures, television recordings, books, histories, etc. Where, during 
contract negotiations, it may be determined to purchase, i.e., 
``specifically acquire,'' unlimited rights in technical data, or to 
lease or obtain a license therein, or to obtain rights in existing data, 
an appropriate clause therefor should be obtained from patent counsel. 
In situations where technical data including computer software are to be 
leased or licensed, the terms of any agreement restricting the 
Government's rights will be included in the contract as either a special 
clause or an agreement annexed thereto. Another clause, the Rights in 
Technical Data (short form) clause further described at 927.402-3(g), 
the text of which is found at 952.227-77, is provided for use in 
research contracts with educational institutions and consultants.

[[Page 328]]

Such contracts may, for example, include those for conducting symposia, 
training, or education, or other contracts not involving possible use of 
proprietary data.
    (h) In contracts involving access to certain categories of DOE-owned 
restricted data, as set forth in 10 CFR part 725, DOE has reserved the 
right to receive reasonable compensation for the use of its inventions 
and discoveries, including its related data and technology. Accordingly, 
in contracts where access to such restricted data is to be provided to 
contractors, the following parenthetical phrase shall be inserted after 
``contract data'' in paragraph (b)(2)(ii) of the clause at 952.227-75, 
after ``technical data'' in paragraph (b)(2) of the clause at 952.227-
77, or after ``technical data'' in paragraph (b)(2)(ii) of the clause at 
952.227-78 as appropriate: ``(except Restricted Data in category C-24, 
10 CFR part 725, in which DOE has reserved the right to receive 
reasonable compensation for the use of its inventions and discoveries, 
including related data and technology).'' In addition, there are other 
types of contract situations (e.g., no cost contracts for studies or 
evaluation) wherein the contractor is given access to restricted data. 
In such contract situations, limitations on the use of such data may be 
appropriate.



927.402-2  Policy.

    The technical data policy is directed toward achieving the following 
objectives:
    (a) Making the benefits of the energy research, development and 
demonstration programs of DOE widely available to the public in the 
shortest practicable time;
    (b) Promoting the commercial utilization of the technology developed 
under DOE programs;
    (c) Encouraging participation by private persons in DOE energy 
research, development, and demonstration programs; and
    (d) Fostering competition and preventing undue market concentration 
or the creation or maintenance of other situations inconsistent with the 
antitrust laws.



927.402-3  Procedures (supply, research, development, or demonstration contracts).

    (a) Known requirements for technical data. Technical data 
requirements are determined in relation to the intended use of the data 
which in turn depends upon the intended use of the contract end item. In 
many contracts for research, the end item may often be a technical 
report or series of such reports, while in contracts beyond research, 
the subject of the contract may be a feasibility model, an engineering 
or advance development model, or a prototype. The extent to which 
required technical data may be needed often depends on the level of 
maturity of design and perfection of the end item, and for a 
demonstration plant or prototype, may include data pertaining to 
performance, operational and environmental testing, repair, maintenance, 
operation, quality assurance, detailed design, logistics, training, etc. 
Known technical data requirements shall be programmatically ascertained 
prior to contracting and shall be included in requests for proposals or 
disclosed during contract negotiations for incorporation as data 
requirements in the contract statement of work.
    (b) Additional requirements for technical data. In contracts for 
research, development, or demonstration, it is not normally possible or 
appropriate for the Government to ascertain all actual needs for 
technical data in advance of contracting. Accordingly, the Additional 
Technical Data Requirements clause at 952.227-73, shall normally be used 
in such contracts (and, if appropriate, in subcontracts) to enable the 
ordering of technical data as the actual need and requirement therefor 
becomes known during the course of the contract. If all technical data 
requirements are known in advance of contracting and are set forth in 
the contract statement of work, this clause need not be used. The 
Additional Technical Data Requirements clause should not normally be 
used in supply contracts because the required technical data therefor 
are ordinarily known in advance and thus are specified in the contract 
statement of work or specification. When the Additional Technical Data 
Requirements clause is

[[Page 329]]

used, the Rights in Technical Data-Long Form clause at 952.227-75 shall 
also be used.
    (c) Clause text. The text of the Additional Technical Data 
Requirements clause is found at 952.227-73.
    (d) Proposals. (1) The policy and procedures for treatment of 
proposal information are set forth in FAR 15.413 for solicited 
proposals, in FAR 15.509 for unsolicited proposals, and 927.70.
    (2) Solicited proposals are to be handled in accordance with the 
procedures of FAR 15.413-2. Evaluation of such proposals outside the 
Government is authorized in accordance with the procedures of FAR 
15.413-2(f) and paragraph (d)(4) below. In order to assure that 
solicited proposals are properly handled, the handling notice of FAR 
15.413-2(e) shall be affixed to a cover sheet attached to each proposal 
upon receipt by DOE. Use of the notice neither alters any obligation of 
the Government, nor diminishes any rights in the Government to use or 
disclose the information.
    (3) Unsolicited proposals are to be handled in accordance with FAR 
15.509. Outside evaluations of such proposals are authorized in 
accordance with the procedures of 927.7000.
    (4) It is DOE policy to have proposals evaluated by the most 
competent persons available in Government. In addition, DOE may meet its 
evaluation needs by having proposals reviewed by evaluators and 
contractor organizations operating or managing government-owned 
facilities. Where it is determined to evaluate a proposal outside the 
Government, such as by consultants, grantees and contractors including 
those who operate or manage Government-owned facilities, the agreement 
of 927.7000 or an equivalent arrangement for the treatment of the 
proposal shall be obtained from the outside evaluator before DOE 
furnishes a copy of the proposal to such person. In addition, care 
should be taken that the required handling notice is affixed to a cover 
sheet attached to the proposal before it is disclosed to the evaluator.
    (5) Should a contract be awarded based on a proposal, it is DOE 
policy, in consideration of the award, to obtain unlimited rights for 
the Government in the technical data contained in the proposal unless 
the prospective contractor marks those portions of the technical 
information which it asserts as ``proprietary data'', or specifies those 
portions of such technical data which are not directly related to or 
will not be utilized in the work to be funded under the contract. 
``Proprietary data'' is defined in 927.401(b). A proposer who receives a 
contract award shall mark the data identified as proprietary by 
specifying the appropriate page numbers to be inserted in the Rights to 
Proposal Data clause of 952.227-82, which clause shall be inserted in 
the contract. Subject to the concurrence of the contracting officer, 
information unrelated to the contract may be deleted from the proposal 
by the contractor. The responsibility, however, of identifying technical 
data as proprietary or deleting it as unrelated, rests with the 
prospective contractor.
    (e) Rights in technical data. (1) The Rights in Technical Data (long 
form) clause set forth at 952.227-75 shall be used in all contracts 
having as a purpose the conduct of research, development, or 
demonstration, or in contracts for supplies, or in any other contract 
where technical data are expected to be first produced under the 
contract, where technical data are specified to be delivered in the 
contract, or where the contract contains the Additional Technical Data 
Requirements clause. Accordingly, all such contracts shall contain the 
Rights in Technical Data (long form) clause at 927.227-75, except as 
noted in 970.2702 and 927.402-3 (f) and (g) and except contracts for 
standard commercial off-the-shelf supplies where technical data such as 
operating or repair manuals are routinely furnished with the supplies.
    (2) Optional paragraph-Limited Rights in Proprietary Data. In 
research, development, or demonstration contracts, and supply contracts 
where it is determined that delivery of proprietary data is necessary 
with limited rights in the Government, the Rights in Technical Data 
(long form) clause at 952.227-75 shall be supplemented by the additional 
paragraph (g) set forth at Alternate I to the clause. It should be noted 
that this paragraph does not entitle

[[Page 330]]

the contractor to place a limited rights legend on any technical data 
furnished to the Government under paragraph (g) unless the contracting 
officer requests in writing delivery of identified technical data 
previously withheld under paragraph (e) of the Rights in Technical Data 
clause. Paragraph (g) provides that proprietary data may be specified in 
the contract as being excluded from the delivery requirements of 
paragraph (e). Alternatively, the limited rights legend specified in 
Alternate I may be made applicable to only those classes of proprietary 
data determined as being necessary for delivery with limited rights. In 
addition, when furnishing proprietary data with the limited rights 
legend, subparagraphs (a), (b) and (c) thereunder may be modified as 
follows. When proprietary data is to be furnished only for evaluation, 
subparagraph (a) of the limited rights legend shall be used, and 
subparagraphs (b) and (c), if otherwise inapplicable, may be deleted. 
When there is a programmatic requirements that proprietary data be 
disclosed to other DOE contractors only for information or use in 
connection with work performed under their contracts, subparagraph (b) 
of the limited rights legend shall be used, and subparagraphs (a) and 
(c) may be deleted if otherwise inapplicable. In either of the foregoing 
examples, the contractor may, if it can show the possibility of a 
conflict of interest because of disclosure of such data to certain 
contractors or evaluators, exclude such contractors or evaluators from 
subparagraphs (a) or (b). If the data is required solely for emergency 
repair or overhaul, subparagraph (c) of the limited rights legend shall 
be retained, and subparagraphs (a) and (b) may be deleted, unless 
otherwise applicable. In the event it is determined that all of the 
subparagraphs (a), (b) and (c) of the limited rights legend are to be 
deleted, the word ``none'' shall be inserted in the legend after the 
colon(:).
    (3) Optional paragraph-Contractor Licensing. In many contracting 
situations the achievement of DOE's objectives would be frustrated if 
the Government, at the time of contracting, did not obtain on behalf of 
responsible third parties and itself limited license rights in and to 
proprietary contract data. Where, for example, the contractor is 
required to license background patents, consideration should be given to 
securing co-extensive license rights to the Government and responsible 
third parties at reasonable royalties, and under appropriate 
restrictions, for contract data which are proprietary data in order to 
practice the technology which is a subject of the contract. When such a 
license right is deemed necessary, the Rights in Technical Data (long 
form) clause at 952.227-75 should be supplemented by the addition of 
paragraph (h) at 952.227-75 Alternate II. Paragraph (h) will normally be 
sufficient to cover proprietary contract data for items and processes 
that were used in the contract and are necessary in order to insure 
widespread commercial use of a subject of the contract. The expression 
``subject of the contract'' is intended to limit the licensing required 
in paragraph (h) below to the fields of technology specifically 
contemplated in the contract effort and may be replaced by a more 
specific statement of the fields of technology intended to be covered in 
the manner described in 41 CFR 9-9.107-5(b)(9) pertaining to 
``Background Patents.'' Where, however, proprietary contract data cover 
the main purpose or basic technology of the research, development, or 
demonstration effort of the contract, rather than subcomponents, 
products or processes which are ancillary to the contract effort, the 
limitations set forth in subparagraphs (h) (1) through (4) should be 
modified or deleted. Paragraph (h) further provides that technical data 
may be specified in the contract as being excluded from or not subject 
to the licensing requirements thereof. This exclusion can be implemented 
by limiting the applicability of the provisions of paragraph (h) to only 
those classes or categories of proprietary data determined as being 
essential for licensing. Although contractor licensing may be required 
under paragraph (h), the final resolution of questions regarding the 
scope of such licenses, the terms thereof, including provions for 
confidentiality and reasonable royalties, is then left to

[[Page 331]]

the negotiation of the parties with resolution of the issues being made, 
if necessary, by a court of competent jurisdiction.
    (f) Rights in Data--Special Works. (1) The clause set forth in 
952.227-76 shall be used in all contracts where the principal purpose or 
a task of the contract is the production of copyrightable works, even 
through such works may incorporate uncopyrighted material or material 
previously copyrighted by the contractor or others. Such contracts 
include those:
    (i) Primarily for production of motion picture or television 
recordings or scripts, musical compositions or arrangements, sound 
tracks or recordings, translations, adaptations, and the like;
    (ii) For books, compilations, surveys, histories, or technology 
information pamphlets;
    (iii) For works pertaining to management studies, support services, 
training, career guidance, or similar functions of DOE; and
    (iv) For works pertaining to guidance or instruction of DOE 
officials or employees in the discharge of official duties.
    (2) The Rights in Data--Special Works clause at 952.227-76 should be 
modified with the assistance of Patent Counsel where the contract calls 
for the editing, translation, addition, or other modification of the 
subject matter of an existing work.
    (g) Rights in Technical Data (short form). The clause set forth in 
952.227-77 may be used in contracts for basic research including grants, 
special research contracts with educational institutions, contracts with 
consultants, contracts for symposia, or for the conduct of training and 
educational programs, and in other contracts of a similar nature. This 
clause shall not be used in any contract where proprietary information 
of the contractor may be utilized in the performance of work under the 
contract; in such instances the Additional Technical Date Requirements 
clause of 952.227-73 and the Rights in Technical Data (long form) clause 
of 952.227-75 shall be used. The short form clause of this section shall 
not be used in situations involving long-term consultancy arrangements 
for work in DOE programs providing opportunities for specialized work 
experience at DOE-owned facilities for scientific, engineering, and 
other employees of private firms and institutions engaged in civilian 
applications of atomic energy.
[49 FR 12004, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984]



927.403  Negotiations and deviations.

    Contracting officers shall contact the Patent Counsel assisting 
their contracting activity, or the Assistant General Counsel for 
Patents, for assistance to the contracting officer in selecting, 
negotiating, or approving appropriate data and copyright clauses in 
accordance with the procedures as set forth in 927.402 and 970.27. In 
particular, advice of Patent Counsel should be obtained regarding the 
appropriateness or modification of optional paragraphs (g) and (h) of 
the Rights in Technical Data (long form) clause, the exclusion of 
specific items of proprietary data from paragraph (f) in said clause, 
and the exclusion of the Additional Technical Data Requirements clause 
of 952.227-73.



           Subpart 927.70--Disclosure of Proposal Information



927.7000  Disclosure outside Government.

    (a) It is DOE policy to have proposals evaluated by the most 
competent persons available in the Goverment. In addition, DOE may meet 
its evaluation needs by having proposals reviewed by evaluators and 
contractor organizations operating or managing government-owned 
facilities. Outside evaluations may be made provided the requirements in 
(b) and (c) below are met. A decision to employ outside evaluators shall 
take into consideration requirements for avoidance of organizational 
conflicts of interest set forth in 909.5 and the competitive 
relationship, if any, between the proposer and the outside evaluator.
    (b) Decisions to evaluate proposals outside the government shall be 
made only by the Source Selection Official with the concurrence of the 
Procurement Executive, Headquarters, for all source evaluation board 
acquisitions,

[[Page 332]]

or by the Senior Program Offical or designee with the concurrence of the 
HCA or his designee for other acquisitions. If the proposal under 
consideration expressly indicates that only Government evaluation is 
authorized and evaluation outside the Government is neverthless desired, 
the proposer shall be advised that DOE may be unable to give full 
consideration to the proposal unless the proposer consents in writing to 
having the proposal evaluated outside the Government.
    (c) Where it is determined to evaluate a proposal outside the 
Government, such as by consultants, grantees or contractors including 
those who grant or manage Government-owned facilities the following 
agreement or an equivalent arrangement for the treatment of the proposal 
shall be obtained from the outside evaluator before DOE furnishes a copy 
of the proposal to such person. In addition, care should be taken that 
the handling notice required by 927.7003 is affixed to a cover sheet 
attached to the proposal before it is disclosed to the evaluator.

                                Agreement

                   Conditions for Evaluating Proposal

    Whenever DOE furnishes a proposal for evaluation, I the recipient 
agree to use the information contained in the proposal only for DOE 
evaluation purposes and to treat the information obtained in confidence. 
This requirement does not apply to information obtained from any source, 
including the proposer, without restriction. Any notice or restriction 
placed on the proposal by either DOE or the originator of the proposal 
shall be conspicuously affixed to any reproduction or abstract thereof 
and its provisions strictly complied with. Upon completion of the 
evaluation, it is agreed all copies of the proposal and abstracts, if 
any, shall be returned to the DOE office which initially furnished the 
proposal for evaluation. Unless authorized by the conracting officer, it 
is agreed the recipient shall not contact the originator of the proposal 
concerning any aspect of its contents.
 Recipient:_____________________________________________________________
 Date:__________________________________________________________________



927.7001  Proposal information.

    Information contained in proposals will be used only for evaluation 
purposes except to the extent such information is generally available to 
the public, is already the property of the Government, or the Government 
already has unrestricted use rights, or is or has been made available to 
the Government from any source, including the proposer or offeror, 
without restriction. The term ``proposal,'' as used in this section, 
includes responses to program opportunity notices (PONs), program 
research and development announcements (PRDAs) and solicitations of a 
similar nature, in addition to requests for proposals (RFPs) and 
unsolicited proposals. As a practical matter, DOE cannot assume any 
responsibility for disclosure or use of any such information unless it 
is identified by the proposer or offeror in accordance with this 
section. Unless a solicitation specifies otherwise, DOE will not refuse 
to consider a solicited proposal or an unsolicited proposal merely 
because the proposal is restrictively marked.



927.7002  Treatment of proposal information.

    (a) A proposal may include technical data and other data, including 
trade secrets and/or privileged or confidential commercial or financial 
information which the offeror does not want disclosed to the public or 
used by the Government for any purpose other than proposal evaluation. 
To protect such data the offeror should specifically identify each page 
including each line or paragraph thereof containing the data to be 
protected and mark the cover sheet of the proposal with the notice set 
forth at FAR 52.215-12, as prescribed at FAR 15.407(c)(8) for solicited 
proposals or FAR 15.509 for unsolicited proposals. Solicitation 
documents shall include instructions to proposers to mark their 
proposals in the prescribed manner.
    (b) A reference to that notice on a proposal cover sheet shall be 
placed on each page to which the notice applies. Data, or abstracts of 
data, marked with that notice will be retained in confidence and used by 
the DOE or its designated representative(s) including Government 
contractors and consultants, as set forth in paragraph (c) of this 
section solely for the purpose of evaluating the proposal. The data so 
marked will not otherwise be disclosed or used without the proposer's 
prior

[[Page 333]]

written permission except to the extent provided in any resulting 
contract, or to the extent required by law. Offerors should be made 
aware of the provisions of paragraph (c) of this section if they desire 
to modify the notice at FAR 52.215-12 or otherwise seek to limit the 
evaluation to the Government only. The restriction contained in the 
notice does not limit the Government's right to use or disclose any data 
contained in the proposal if it is obtainable from any source, including 
the offeror, without restriction. Although it is the policy of the DOE 
to treat all proposals as confidential, the Government assumes no 
liability for disclosure or use of unmarked data and may use or disclose 
such data for any purpose. See FAR 15.1001(b) regarding disclosure to 
other offerors.
    (c) Should a contract be awarded based on a proposal, it is DOE 
policy, in consideration of the award, to obtain unlimited rights for 
the Government in the technical data contained in the proposal unless 
the prospective contractor marks those portions of the technical 
information which he asserts ``proprietary data,'' or specifies those 
portions of such technical data which are not directly related to or 
will not be utilized in the work to be funded under the contract. 
``Proprietary data'' is defined in 927.401. An offeror who receives a 
contract award shall mark the data identified as proprietary by 
specifying the appropriate page numbers to be inserted in the Rights to 
Proposal Data clause of 952.227-82, which clause shall be inserted in 
the contract. Subject to the concurrence of the contracting officer, 
information unrelated to the contract may be deleted from the proposal 
by the contractor. The responsibility, however, of identifying technical 
data as proprietary or deleting it as unrelated, rests with the 
prospective contractor.
    (d) The clause at 952.227-82 shall be included in any contract which 
resulted from a proposal that was the basis of negotiation and award of 
the contract. This clause is intended to apply only to technical data 
and not to other data such as privileged or confidential commercial or 
financial information.



927.7003  Handling notice.

    In order that proposals may be handled in confidence consistent with 
the policies set forth in this section and pursuant to 927.402-3(d)(2), 
the notice at FAR 15.413-2(e) for solicited proposals and FAR 15.509(d) 
for unsolicited proposals shall be affixed to a cover sheet attached to 
each proposal upon receipt by DOE. Use of the notice neither alters any 
obligation of the Government, nor diminishes any rights in the 
Government to use or disclose data or information.



927.7004  Identification of proprietary data in proposals.



927.7004-1  Solicited proposals.

    Even though the statement of work contained in a solicitation sets 
forth the known requirements for technical data, i.e., technical data 
which will be specified to be delivered, there is no assurance that the 
contractor will deliver all of this data because paragraph (e) of the 
Rights in Technical Data (long form) clause at 952.227-75 permits the 
contractor to withhold proprietary data from delivery. In order to 
ascertain the technical data the proposer intends to withhold as 
proprietary data, and as an aid in determining whether to include the 
provision for limited rights in proprietary data set forth in optional 
paragraph (g) of the Rights in Technical Data (long form) clause, the 
provision set forth in 952.227-83 shall be included in the solicitation. 
This provision explains that solicitations will include DOE's known 
requirements for technical data, and that the proposer must submit a 
list identifying to the best of its knowledge which of this data will be 
withheld as proprietary data, or state that no technical data will be 
withheld. The submission of such a list does not constitute a 
stipulation or determination by the Government that the data identified 
therein are in fact proprietary. In addition, the provision to be 
included in the solicitation refers to the Additional Technical Data 
Requirements clause at 952.227-73, as being included in the proposed 
contract where, due to programmatic considerations, it is contemplated 
that all of the requirements for technical data

[[Page 334]]

will not be known at the time of contracting. When a proposer 
specifically identifies the proprietary data to be withheld, the 
contracting officer shall determine as advised by the appropriate 
program manager, whether:
    (a) the Government needs limited rights in the proprietary data, in 
which case the optional paragraph (g) will be included in the Rights in 
Technical Data (long form) clause;
    (b) the Government needs to require the contractor to license 
proprietary data to the Government and responsible third parties, in 
which case optional paragraph (h) will be included in the Rights in 
Technical Data (long form) clause; and
    (c) the Government needs unlimited rights in the proprietary data, 
in which case negotiations may be held to purchase or obtain a suitable 
license to the proprietary data.



927.7004-2  Solicitations.

    The provision at 952.227-83 shall normally be included in 
solicitations which may result in contracts calling for research, 
development, or demonstration work or solicitations for supplies in 
which delivery of required technical data is contemplated.



927.7004-3  Unsolicited proposals.

    The contracting officer, during contract negotiations, shall 
identify technical data which will be required to be furnished under the 
contract. The proposer shall be required to submit a list identifying, 
to the best of his knowledge, which of this data will be withheld as 
proprietary under paragraph (e) of the Rights in Technical Data (long 
form) clause, or to state that no technical data will be withheld. The 
contracting officer shall then make the determinations, in the same 
manner as set forth in 927.7004-1 for solicited proposals, pertaining to 
the proprietary data identified to be withheld.



927.7005  Required notice of right to request patent waiver.

    Offerors are to be provided with notice of the right to request, in 
advance of or within 30 days after the effective date of contracting, a 
waiver of all or any part of the rights of the United States with 
respect to subject inventions. In no event will the fact that an offeror 
has requested such a waiver be a consideration in the evaluation of his 
offer or the determination of his acceptability. Accordingly, the notice 
at 952.227-84 shall be given to all prospective contractors and shall be 
inserted in all solicitations which may result in contracts calling for 
research, development, or demonstration work.



PART 928--BONDS AND INSURANCE--Table of Contents




                          Subpart 928.1--Bonds

Sec.
928.101-1  Policy on use.
928.103-3  Payment bonds.
928.103-70  Review of performance and payment bonds for other than 
          construction.

                        Subpart 928.3--Insurance

928.301  Policy.
928.370  Service-type insurance policies.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12010, Mar. 28, 1984, unless otherwise noted.



                          Subpart 928.1--Bonds

    Source:  61 FR 41708, Aug. 9, 1996, unless otherwise noted.



928.101-1  Policy on use.

    In addition to the restriction on use of bid guarantees in FAR 
28.101-1(a), a bid guarantee may be required only for fixed price or 
unit price contracts entered into as a result of sealed bidding. They 
may not be required for negotiated contracts.



928.103-3  Payment bonds.

    A determination that is in the best interest of the Government to 
require payment bonds in connection with other than construction 
contracts may be made by the contracting officer on individual 
acquisitions.



928.103-70  Review of performance and payment bonds for other than construction.

    A performance or payment bond, other than an annual bond, shall not 
antedate the contract to which it pertains.

[[Page 335]]



                        Subpart 928.3--Insurance



928.301  Policy.

    The DOE policies and procedures for indemnification of DOE 
contractors are set forth in FAR Part 50 and 950.



928.370  Service-type insurance policies.

    (a) Service-type insurance policies are cost-reimbursement type 
contracts or subcontracts in which the insurer provides claim and loss 
adjustment services on a cost reimbursement basis, which satisfies state 
and Federal insurance requirements.
    (b) Service-type insurance policies may be used with contracting 
officer approval, when one or more of the following conditions are 
present:
    (1) Pure risk commercial insurance is not available or, if 
available, cost is not considered reasonable;
    (2) Inherent risks in the contract are new and a part of the process 
of commercialization;
    (3) The service-type insurance is needed to implement jointly funded 
projects; or
    (4) The service-type insurance arrangement is considered in the 
Government's best interest.



PART 931--CONTRACT COST PRINCIPLES AND PROCEDURES--Table of Contents




                      Subpart 931.1--Applicability

Sec.
931.102  Fixed-price contracts.

         Subpart 931.2--Contracts With Commercial Organizations

931.205-18  Independent research and development (IR&D) and bid and 
          proposal (B&P) costs.
931.205-32  Precontract costs.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).



                      Subpart 931.1--Applicability



931.102  Fixed-price contracts.

    The intent of the first sentence of FAR 31.102 is that applicable 
subparts of FAR Part 31 shall be used by the Government in (a) pricing 
fixed-price prime contracts and modifications, (b) evaluating the 
reasonableness of a prime contractor's (or prospective prime 
contractor's) proposed subcontract (or subcontract modification) prices, 
and (c) determining the allowability of contractor payments to 
subcontractors in accordance with the provisions of FAR 31.204(b).
[49 FR 12011, Mar. 28, 1984]



         Subpart 931.2--Contracts With Commercial Organizations



931.205-18  Independent research and development (IR&D) and bid and proposal (B&P) costs.

    (c)(2) IR&D costs are recoverable under DOE contracts to the extent 
they are reasonable, allocable, not otherwise unallowable, and have 
potential benefit or relationship to the DOE program. The term ``DOE 
program'' encompasses the DOE total mission and its objectives. B&P 
costs are recoverable under DOE contracts to the extent they are 
reasonable, allocable, and not otherwise unallowable.
[60 FR 30004, June 7, 1995]



931.205-32  Precontract costs.

    (a) To the extent practical, known expenditures of precontract costs 
under DOE contracts should be governed by establishing advance 
understandings as contemplated by FAR 31.109. Contracts that include 
authorized precontract costs shall include the ``Date of Incurrence of 
Cost'' clause specified at 952.231-70.
    (b) The following limitations apply to establishment of advance 
understandings relative to precontract costs:
    (1) Precontract cost authorizations shall not be used to cover a 
period in excess of 15 days, unless a longer period is approved by the 
HCA based upon a written finding that such an allowance is reasonable, 
and shall not be extended or renewed. A copy of the findings shall be 
forwarded to the Procurement Executive at the time of approval. If 
prolonged coverage is necessary, a letter contract shall be issued.
    (2) All precontract cost authorizations shall be reviewed and 
approved at a management level above the contracting officer.

[[Page 336]]

    (3) Retroactive precontract cost authorization and the predating of 
contractual agreements shall not be used.
    (4) Precontract cost authorizations shall not authorize the delivery 
or furnishing of any goods or services from a contractor until after the 
contract is executed.
[49 FR 12011, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984]



PART 932--CONTRACT FINANCING--Table of Contents




                         Subpart 932.1--General

Sec.
932.102  Description of contract financing methods.

          Subpart 932.3--Loan Guarantees for Defense Production

932.304-2  Certificate of eligibility.

                     Subpart 932.4--Advance Payments

932.402  General.
932.407  Interest.

             Subpart 932.5--Progress Payments Based on Costs

932.501-2  Unusual progress payments.

                      Subpart 932.6--Contract Debts

932.605  Responsibilities and cooperation among Government officials.

                   Subpart 932.8--Assignment of Claims

932.803  Policies.

                      Subpart 932.9--Prompt Payment

932.970  Implementing DOE policies and procedures.

              Subpart 932.70--DOE Loan Guarantee Authority

932.7002  Authority.
932.7003  Policies.
932.7004  Procedures.
932.7004-1  Guaranteed loans for civilian programs.
932.7004-2  Criteria.
932.7004-3  Eligibility.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12011, Mar. 28, 1984, unless otherwise noted.



                         Subpart 932.1--General



932.102  Description of contract financing methods. (DOE coverage--paragraph (e))

    (e)(2) Progress payments based on a percentage or stage of 
completion may be authorized by the Head of the Contracting Activity 
when a determination is made that progress payments based on costs 
cannot be practically employed and that there are adequate safeguards 
provided for the administration of progress payments based on a 
percentage or stage of completion.
[61 FR 41708, Aug. 9, 1996]



          Subpart 932.3--Loan Guarantees for Defense Production



932.304-2  Certificate of eligibility.

    (h) Guaranteed loan applications shall be authorized and transmitted 
to the Federal Reserve Bank only by the Secretary or designee specified 
for that purpose.



                     Subpart 932.4--Advance Payments



932.402  General.

    (e)(1) The Head of the Contracting Activity or designee shall have 
the responsibility and authority for making findings and determinations, 
and for approval of contract terms concerning advance payments.
    (2) Before authorizing any advance payment arrangements, the 
approving official shall obtain the advice, and other inputs of the 
servicing finance office.



932.407  Interest.

    (d)(4) Advance payments may be made without interest under cost-
reimbursement contracts for construction or engineering services.



             Subpart 932.5--Progress Payments Based on Costs



932.501-2  Unusual progress payments.

    (a)(3) The Head of the Contracting Activity shall forward all 
requests which are considered favorable, with supporting information, to 
the Chief

[[Page 337]]

Financial Officer, Headquarters, will approve or deny the request.
    (d) Requests for unusual progress payments will not be considered as 
a handicap or adverse factor in the award of a contract; provided the 
bid or proposal is not conditioned on approval of such request.
[49 FR 12011, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



                      Subpart 932.6--Contract Debts



932.605  Responsibilities and cooperation among Government officials.

    (b) The DOE contracting officer has primary responsibility for 
determining the amount of contract debt and notifying the cognizant 
finance office of such debt due the Government. The servicing DOE 
finance office making payments under the contract has primary 
responsibility for debt collection.



                   Subpart 932.8--Assignment of Claims



932.803  Policies.

    (d) In the case of prime contracts, when it has been determined that 
the financing of contracts will be facilitated in the interest of DOE 
programs, it is the policy of DOE that such contracts provide, or be 
amended without consideration (see Assignment of Claims Act of 1940) to 
provide, in conformance with FAR 32.804, that payments to be made to an 
assignee shall not be subject to reduction or setoff. In the case of 
subcontracts, when loans are made for the purpose of financing 
performance of subcontracts under DOE prime contracts, financing 
institutions or the Government as guarantor in those instances in which 
such loans are guaranteed should not be required to incur risks of loss 
by reason of possible diversion of assigned subcontracts proceeds for 
payment of other claims of the prime contractor against the borrower, 
otherwise unrelated to the assigned subcontracts. The Head of the 
Contracting Activity shall require the adoption of these policies and 
practices by DOE prime contractors with respect to DOE subcontract work. 
The Head of the Contracting Activity should inform the Chief Financial 
Officer, Headquarters of each DOE contractor who is unwilling to adopt 
policies consistent with this paragraph and the reasons given in support 
of the contractor's position.
[49 FR 12011, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



                      Subpart 932.9--Prompt Payment



932.970  Implementing DOE policies and procedures.

    (a) Invoice payments--(1) Contract Settlement Date. For purposes of 
determining any interest penalties under cost-type contracts, the 
effective date of contract settlement shall be the effective date of the 
final contract modification issued to acknowledge contract settlement 
and to close out the contract.
    (2) Constructive acceptance periods. Where the contracting officer 
determines, in writing, on a case-by-case basis, that it is not 
reasonable or feasible for DOE to perform the acceptance or approval 
function within the standard period, the contracting officer should 
specify a longer constructive acceptance or approval period, as 
appropriate. Considerations include, but are not limited to, the nature 
of supplies or services involved, geographical site location, inspection 
and testing requirements, shipping and acceptance terms, and available 
DOE resources.
    (b) Contract financing payments. Contracting officers may specify 
payment due dates that are less than the standard 30 days when a 
determination is made, in writing, on a case-by-case basis, that a 
shorter contract financing payment cycle will be required to finance 
contract work. In such cases, the contracting officer should coordinate 
with the finance and program officials that will be involved in the 
payment process to ensure that the contract payment terms to be 
specified in solicitations and resulting contract awards can be 
reasonably met. Consideration should be given to geographical 
separation, workload, contractor ability to submit a proper request, and 
other factors that could affect timing of payment. However, payment due 
dates that are less than 7 days for progress

[[Page 338]]

payments or less than 14 days for interim payments on cost-type 
contracts are not authorized.
[61 FR 41708, Aug. 9, 1996]



              Subpart 932.70--DOE Loan Guarantee Authority



932.7002  Authority.

    Guaranteed loan applications shall be authorized and transmitted to 
the Federal Reserve Board only by the Secretary, or designee specified 
for that purpose, and only when made pursuant to enabling legislation or 
other authority; e.g., by executive order or regulation.



932.7003  Policies.

    The following policies governing the exercise of its loan guarantee 
authority have been established by DOE:
    (a) The use of the loan guarantee authority is not restricted to 
contracts or subcontracts of any particular type or class. Each case is 
to be evaluated on its own merits and under the particular circumstances 
applicable thereto.
    (b) The fact that a contract has been awarded as a result of 
competitive bidding should not, of itself, render the loan ineligible 
for guarantee by DOE if the contractor is financially responsible and 
its need for working capital is the result of the impact of a defense 
program or any other DOE program for which guaranteed loans are 
authorized.
    (c) The guarantee authority should, in general, not be used in 
connection with loans to contractors required to furnish performance 
bonds, except in those cases in which the time likely to be required for 
the surety or DOE to take over in the event of default will result in 
delays which cannot be tolerated by the particular program concerned. 
When performance bonds have been furnished, the surety shall be required 
to subordinate its rights in favor of the guaranteed loan.
    (d) The criterion that the materials or services to be provided 
cannot readily be acquired from alternative sources does not require the 
finding that the materials or services are absolutely unobtainable 
elsewhere. The criterion should be so applied as to permit guarantees of 
loans when, although the materials or services can be obtained 
elsewhere, such factors as the urgency of supply schedules, technical 
capacity of the contractor, comparative prices, and time and expense 
involved in reissuing the contract, including termination payment, 
establish that it is to the Government's advantage not to resort to 
alternative sources merely because the contractor or subcontractor may 
require a guaranteed loan.
    (e) If it is known at the time the contract is to be awarded that 
the low offeror who is technically qualified and competent to furnish 
the required materials and services will require a guaranteed loan, the 
contracting officer should obtain appropriate advice and in reaching a 
decision should consider at least the following:
    (1) The savings to be realized by awarding the contract to the low 
offeror;
    (2) The risk to the Government in guaranteeing a loan; and
    (3) The likelihood, if award is made to the second low offeror, of 
that offeror's applying for a guaranteed loan at a later date.

Extreme care should be exercised in rejecting a low bid or proposal 
simply because the low offeror requires a guaranteed loan.
    (f) The amount of the loan should bear reasonable relationship to 
such factors as the value and terms of the contract, the probable 
investment required to be made by the contractor in payrolls and 
inventories, the frequency with which contract payments are to be made, 
and the borrower's current working capital position.
    (g) Borrowings for working capital purposes under guaranteed loans 
shall be limited to the amount necessary to perform the contract for 
which the loan is sought. In order that the contractor will also use its 
own funds in the performance of the contracts, amounts outstanding under 
the loan or line-of-credit shall be limited to an amount not to exceed 
90 percent of the borrower's investment in its contracts, regardless of 
the total amount of the loan or line of credit authorized. The 
borrower's investment includes all items for which the borrower would be 
entitled to payment on performance or termination of contracts, but does 
not

[[Page 339]]

include any items for which no work has been done nor expenditures made.
    (h) Unless there are exceptional circumstances, the loan should 
mature not later than 30 days after the estimated date of final payment 
under the contract.
[49 FR 12011, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



932.7004  Procedures.



932.7004-1  Guaranteed loans for civilian programs.

    The procedures for authorizing a guaranteed loan under legislation 
other than section 301 of the Defense Production Act of 1950 (50 U.S.C. 
App. 2091) shall be essentially the same as those set forth in FAR 
32.304, Procedures, FAR 32.305, Loan Guarantees for Terminated 
Contracts, and FAR 32.306 Loan Guarantee for Subcontacts; except that 
any contrary provisions required by enabling legislation authorizing the 
loan shall govern.



932.7004-2  Criteria.

    (a) The materials or services to be furnished by the contractor are 
necessary to the Government interest.
    (b) The materials or services cannot as a practical matter be 
obtained from alternate sources without delay or impeding the 
Government's interest, except that no small business concern shall be 
held ineligible for the issuance of such guarantee by reason of 
alternative sources of supply.
    (c) The contractor has demonstrated its inability to obtain the 
necessary financing in conventional credit channels without the 
guarantee.
    (d) There is reasonable assurance that the loan can be repaid.
    (e) The contractor is competent to perform the contract.
[49 FR 12011, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



932.7004-3  Eligibility.

    The applicant's eligibility for a guaranteed loan will be based on:
    (a) Contracting officer determinations and findings regarding items 
(a), (b) and (e) in 932.7004-2 as incorporated in a Certificate of 
Eligibility (FAR 32.304-2); and
    (b) The Chief Financial Officer's determination for items (c) and 
(d) in 932.7004-2 based on information contained in the application, the 
Federal Reserve Bank's report, and information furnished by the 
contracting activity concerned.
[49 FR 12011, Mar. 28, 1984, as amended at 59 FR 9106, Feb. 25, 1994]



PART 933--PROTESTS, DISPUTES, AND APPEALS--Table of Contents




                         Subpart 933.1--Protests

933.103  Protests to the agency.
933.104  Protests to GAO.
933.106  Solicitation provisions.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  51 FR 31336, Sept. 3, 1986, unless otherwise noted.



                         Subpart 933.1--Protests

    Source:  61 FR 41708, Aug. 9, 1996, unless otherwise noted.



933.103  Protests to the agency. (DOE coverage--paragraphs (f), (i), (j), and (k))

    (f) If FAR 33.103(f) requires that award be withheld or performance 
be suspended or the awarded contract be terminated pending resolution of 
an agency protest, authority to award and/or continue performance of the 
protested contract may be requested by the Head of the Contracting 
Activity (HCA), concurred in by counsel, and approved by the Procurement 
Executive.
    (i)(1) Protests filed with the contracting officer before or after 
award shall be decided by the Head of the Contracting Activity except 
for the following cases, which shall be decided by the Procurement 
Executive:
    (i) The protester requests that the protest be decided by the 
Procurement Executive.
    (ii) The HCA is the contracting officer of record at the time the 
protest is filed, having signed either the solicitation where the award 
has not been made, or the contract, where the award or nomination of the 
apparent successful offeror has been made.
    (iii) The HCA concludes that one or more of the issues raised in the 
protest

[[Page 340]]

have the potential for significant impact on DOE acquisition policy.
    (2) Upon receipt of a protest requesting a decision by the 
Procurement Executive, the contracting activity shall immediately 
provide a copy of the protest to the Office of Clearance and Support.
    (j) The Department of Energy encourages direct negotiations between 
an offeror and the contracting officer in an attempt to resolve 
protests. In those situations where the parties are not able to achieve 
resolution, the Department favors the use of alternative dispute 
resolution (ADR) techniques to resolve protests. A protest requesting a 
decision at the Headquarters level shall state whether the protester is 
willing to utilize ADR techniques such as mediation or nonbinding 
evaluation of the protest by a neutral. Upon receipt of a protest 
requesting a decision at the Headquarters level, the Office of Clearance 
and Support will explore with the protester whether the use of ADR 
techniques would be appropriate to resolve the protest. Both parties 
must agree that the use of such techniques is appropriate. If the 
parties do not mutually agree to utilize ADR to resolve the protest, the 
protest will be processed in accordance with the procedures set forth in 
paragraph (k).
    (k) Upon receipt of a protest lodged with the Department, the 
contracting officer shall prepare a report similar to that discussed in 
FAR 33.104(a)(3)(iii). In the case of a protest filed at the 
Headquarters level, the report shall be forwarded to the Office of 
Clearance and Support within 21 calendar days of being notified of such 
a protest with a proposed response to the protest. The Procurement 
Executive (for protests at the Headquarters level or those specific HCA 
protests cited in paragraph (i)(1) of this section) or an HCA (for 
protests at the contracting activity level) will render a decision on a 
protest within 35 calendar days, unless a longer period of time is 
determined to be needed.



933.104  Protests to GAO. (DOE coverage--paragraphs (a), (b), (c), and (g))

    (a)(2) The contracting officer shall provide the notice of protest.
    (b) Protests before award. (1) When the Department has received 
notice from the GAO of a protest filed directly with the GAO, a contract 
may not be awarded until the matter is resolved, unless authorized by 
the Head of the Contracting Activity in accordance with FAR 33.104(b). 
Before the Head of the Contracting Activity authorizes the award, the 
required finding shall be concurred in by the DOE counsel handling the 
protest, endorsed by the Senior Program Official, and approved by the 
Procurement Executive. The finding shall address the likelihood that the 
protest will be sustained by the GAO.
    (c) Protests after award. Before the Head of the Contracting 
Activity authorizes performance, the finding required by FAR 
33.104(c)(2) shall be concurred in by the DOE counsel handling the 
protest, endorsed by the Senior Program Official, and approved by the 
Procurement Executive.
    (g) Notice to GAO. (1) The report to the GAO regarding a decision 
not to comply with the GAO's recommendation, discussed at FAR 33.104(f), 
shall be provided by the HCA making the award, after approval of the 
Procurement Executive. If a DOE-wide policy issue is involved, the 
report shall be provided by the Procurement Executive.
    (2) It is the policy of the Department to comply promptly with 
recommendations set forth in Comptroller General Decisions except for 
compelling reasons.
    (3) The GAO does not have jurisdiction to consider subcontractor 
protests. 933.106 Solicitation provisions.



933.106  Solicitation provisions.

    (a) The contracting officer shall supplement the provision at FAR 
52.233-2, Service of Protest, in solicitations for other than simplified 
acquisitions by adding the provision at 48 CFR 952.233-2.
    (b) The contracting officer shall include the provision at 48 CFR 
952.233-4 in solicitations for purchases above the simplified 
acquisition threshold.
    (c) The contracting officer shall include the provision at 48 CFR 
952.233-5 in solicitations for purchases above the simplified 
acquisition threshold.

[[Page 341]]



             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING





PART 935--RESEARCH AND DEVELOPMENT CONTRACTING--Table of Contents




Sec.
935.010  Scientific and technical reports.
935.016  Research opportunity announcements.
935.016-1  Scope.
935.016-2  Applicability.
935.016-8  Selection of proposals.
935.070  Contract clauses.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12016, Mar. 28, 1984, unless otherwise noted.



935.010  Scientific and technical reports.

    (c) All research and development contracts which require submission 
of scientific and technical reports, shall include an instruction 
requiring the contractor to submit all scientific and technical reports, 
and any other notices or reports relating thereto, to the following 
address: U.S. Department of Energy, Office of Scientific and Technical 
Information, P.O. Box 62, Oak Ridge, TN 37831. The phrase ``any other 
notices or reports relating thereto'' does not include notices or 
reports concerning administrative matters such as contract cost or 
financial data and information.
    (d) Contractors shall be required to submit with each report a 
completed DOE Form 1332.15, ``DOE and Major Contractor Recommendations 
for Announcement and Distribution of Documents,'' except when the 
contract is with an educational institution, in which case the 
contractor shall be required to submit with each report a completed DOE 
Form 1332.16, ``University Contractor, Grantee and Cooperative Agreement 
Recommendations for Announcement and Distribution of Documents.''
[56 FR 41965, Aug. 26, 1991]



935.016  Research opportunity announcements.



935.016-1  Scope.

    (a) FAR 35.016 sets forth the policies and procedures for 
contracting for research through the use of broad agency announcements 
as authorized by the Competition in Contracting Act of 1984 (CICA) (41 
U.S.C. 259(b)(2)) and Federal Acquisition Regulation FAR 6.102(d)(2). 
Within DOE, broad agency announcements will be designated as Research 
Opportunity Announcements (ROAs).
    (b) Research Opportunity Announcements are a form of competitive 
solicitation under which DOE's broad mission and program-level research 
objectives are defined; proposals which offer meritorious approaches to 
those objectives are requested from all offerors capable of satisfying 
the Government's needs; those proposals are evaluated by scientific or 
peer review against stated specific evaluation criteria; and selection 
of proposals for possible contract award is based upon that evaluation, 
the importance of the research to the program objectives, and funds 
availability.
[61 FR 41709, Aug. 9, 1996]



935.016-2  Applicability.

    (a) This section applies to all DOE Headquarters and field program 
organizations which, by virtue of their statutorily mandated mission or 
other such authority as may exist, support energy or energy-related 
research activities through contractual relationships.
    (1) The ROA may be used as a competitive solicitation procedure 
through which DOE acquires basic and applied research in support of its 
broad mission and program-level research objectives, and these 
objectives may be best achieved through relationships where contractors 
pursue diverse and dissimilar solutions and approaches to scientific and 
technological areas related to DOE's missions and programs.
    (2) The ROA shall not be used as a solicitation method when one or 
more of the following conditions exist:
    (i) In accordance with the Federal Grant and Cooperative Agreement 
Act, Public Law 97-258, the principal purpose of the relationship will 
be assistance;
    (ii) The purpose of the research is to accelerate the demonstration 
of the technical, operational, economic, or

[[Page 342]]

commercial feasibility and environmental acceptability of particular 
energy technologies, systems, subsystems, and components that would 
appropriately be acquired by Program Opportunity Notices (PONs) in 
accordance with 48 CFR 917.72;
    (iii) The research is required in support of a specific project area 
within an energy program which appropriately would be acquired by 
Program Research and Development Announcements (PRDAs) in accordance 
with 48 CFR 917.73;
    (iv) The research requirements can be sufficiently defined to allow 
the use of contracting by negotiation in accordance with FAR part 15;
    (v) The purpose of the research is the acquisition of goods and 
services related to the development of a specific system or hardware 
acquisition; or,
    (vi) Any funds to be obligated to a resulting contract will be used 
to conduct or support a conference or training activity.
    (b) The following limitations are applicable to the use of ROAs:
    (1) The use of broad agency announcements for the acquisition of 
that part of development not related to the development of a specific 
system or hardware is authorized by FAR 35.016(a). Notwithstanding that 
authorization, ROAs shall be used within DOE only to acquire basic and 
applied research.
    (2) Proposals shall not be solicited from, and contracts shall not 
be awarded to, any specific entity which operates a Government-owned or 
-controlled research, development, special production, or testing 
establishment, such as DOE's management and operating contractor 
facilities, Federally Funded Research and Development Centers chartered 
by other agencies, or other such entities. This limitation shall not be 
used to preclude the parent organization of the entity operating the 
Government-owned or -controlled facility, its subsidiaries, other 
divisions, or other related business affiliates from proposing, or 
receiving awards, under DOE's ROA solicitations, provided that any 
proposed resources (personnel, facilities, and other resources) used in 
the management and operation of the Government-owned or -controlled 
facility have been approved for use in the ROA effort by the sponsoring 
agency.
[61 FR 41709, Aug. 9, 1996]



935.016-8  Selection of proposals.

    (a) After considering the evaluation findings, the importance of the 
proposed research to the program objectives, and funds availability, the 
Selection Official shall determine whether a specific proposal warrants 
selection for negotiation and award of a contract. The decision of the 
Selection Official shall be documented in writing and shall address, as 
appropriate, such issues as:
    (1) The scientific and technical merit of the proposal in relation 
to the ROA evaluation criteria;
    (2) The qualifications, capabilities, and experience of the proposed 
personnel; technical approach; facilities; and where applicable, cost 
participation by the offeror (or any combination of the above);
    (3) The importance of the proposed research to the program 
objectives;
    (4) Which areas of the proposal, whether in whole or in part, have 
been selected for funding, and the amount of that funding; and,
    (5) Assurances that any other requirements which are imposed by 
statute, regulation, or internal directives relating to the specific 
research activities and which are properly the responsibility of the 
program office have been satisfied.
    (b) Absent extenuating circumstances, selection decisions regarding 
any individual proposal should be made within six (6) months after 
receipt of the proposal. Proposals which have been evaluated may be 
accumulated to allow for a consolidated selection decision so long as 
not more than six (6) months have passed since the receipt of any of the 
proposals so accumulated.
    (c) The cognizant DOE program official shall notify successful and 
unsuccessful offerors of any selection/non-selection decisions. These 
notices shall be made in writing promptly after the

[[Page 343]]

decision is made, and shall, at a minimum, state in general terms, the 
basis for the determination.
[61 FR 41710, Aug. 9, 1996]



935.070  Contract clauses.

    Insert the clause at 952.235-70, Key Personnel, in research and 
development contracts under which performance is largely dependent on 
the expertise of specific key personnel. To prevent administrative 
burden, the list should be as limited as possible.
[49 FR 12016, Mar. 28, 1984, as amended at 59 FR 9107, Feb. 25, 1994]



PART 936--CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS--Table of Contents




     Subpart 936.2--Special Aspects of Contracting for Construction

Sec.
936.202  Specifications.

               Subpart 936.6--Architect-Engineer Services

936.602-70  DOE selection criteria.
936.609-3  Work oversight in architect-engineer contracts.

     Subpart 936.7--Standard and Optional Forms for Contracting for 
 Construction, Architect-Engineer Services, and Dismantling, Demolition 
                       or Removal of Improvements

936.702  Forms for use in contracting for architect-engineer services.

                Subpart 936.71--Inspection and Acceptance

936.7100  Scope of subpart.
936.7101  Construction contracts.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12016, Mar. 28, 1984, unless otherwise noted.



     Subpart 936.2--Special Aspects of Contracting for Construction



936.202  Specifications.

    (a) To support all invitations for bids, plans and specifications 
will be available on request to all prospective bidders, including 
general contractors, subcontractors, and material and equipment 
suppliers. Where the cost of reproduction is $10 or more, the charge 
shall be a minimum of $10 and subject to a maximum of $500, depending 
upon the size of the project and the number of drawings and the volume 
of specifications involved. Where the cost of reproduction is less than 
$10, the contracting officer has authority to make distribution at cost 
of reproduction, or free of charge, as a particular situation dictates.
    (b) No refund for the return of plans and specifications will be 
made except when the invitation is canceled. Under such circumstances, 
refund of payments will be made upon return of the plans and 
specifications in good condition to the issuing office.
    (c) Plans and specifications will be issued without charge to such 
organizations as The Associated General Contractors of America, American 
Road Builders' Association, Dodge Reports, Blue Reports, Brown's 
Letters, Inc., builders and contractors exchanges in the locality in 
which the project is to be constructed, and others that maintain public 
plan display rooms.
    (d) Payments received for plans and specifications shall be handled 
in accordance with the regulations prescribed by the General Accounting 
Office in sections 3020-10 and 3030 of Title 7 of GAO Manual for 
Guidance of Federal Agencies.
    (e) If the contracting officer desires to have the architect-
engineer or construction manager handle the furnishing of plans and 
specifications and payments therefor, the invitations for bids should so 
state, and the architect-engineer or construction management contract 
shall provide the manner in which the receipts are to be handled, 
generally as a credit to the contract.
    (f) No charge will be made to original receivers of plans and 
specifications for revised sheets of drawings and revised pages of 
specifications which are issued by amendments to invitations.
    (g) Plans and specifications may be issued in complete sets only, or 
in complete sets and parts of sets, as the Head of the Contracting 
Activity determines to be best. If less than complete sets of plans and 
specifications are issued, the distribution should be based on an 
applicant's request for specific pages and drawing sheets.

[[Page 344]]

    (h) When a non-refundable fee is to be charged, a provision 
substantially the same as 952.236-72 shall be included in the 
solicitation.
[49 FR 12016, Mar. 28, 1984, as amended at 60 FR 47308, Sept. 12, 1995]



               Subpart 936.6--Architect-Engineer Services



936.602-70  DOE selection criteria.

    Contracting officers or architect-engineer evaluation boards shall 
apply the evaluation criteria contained in this subsection, as 
appropriate, and any special criteria developed for individual 
selections. When special and additional criteria are to be used, they 
shall be set forth in the public announcement required by 936.601, and a 
written justification for their use shall be placed in the DOE file 
maintained for the project.
    (a) General qualifications, including:
    (1) Reputation and standing of the firm and its principal members;
    (2) Experience and technical competence of the firm in comparable 
work;
    (3) Past record in performing work for DOE, other Government 
agencies, and private industry, including projects or contracts 
implemented with no overruns; performance from the standpoint of cost 
including cost overruns (last 5 years); the nature, extent, and 
effectiveness of contractor's cost reduction program; quality of work; 
and ability to meet schedules including schedule overruns (last 5 years) 
(where applicable);
    (4) The volume of past and present workloads;
    (5) Interest of company management in the project and expected 
participation and contribution of top officials;
    (6) Adequacy of central or branch office facilities for the proposed 
work, including facilities for any special services that may be 
required;
    (7) Geographic location of the home office and familiarity with the 
locality in which the project is located:
    (b) Personnel and organizations. (1) Specific experience and 
qualifications of personnel proposed for assignment to the project, 
including, as required for various phases of the work:
    (i) Technical skills and abilities in planning, organizing, 
executing, and controlling;
    (ii) Abilities in overall project coordination and management; and
    (iii) Experience in working together as a team;
    (2) Proposed project organization, delegations of responsibility, 
and assignments of authority;
    (3) Availability of additional competent, regular employees for 
support of the project, and the depth and size of the organization so 
that any necessary expansion or acceleration could be handled 
adequately;
    (4) Experience and qualifications of proposed consultants and 
subcontractors; and
    (5) Ability to assign adequate qualified personnel from the proposed 
organization (firms own organization, joint-venture organizations, 
consulting firms etc.) including key personnel and a competent 
supervising representative.
    (c) Additional (or special) criteria developed for the specific 
project shall be considered and evaluated as may be appropriate.



936.609-3  Work oversight in architect-engineer contracts.

    In addition to the clause at FAR 52.236-24, the contracting officer 
shall insert the clause at 952.236-71 in architect-engineer contracts.



     Subpart 936.7--Standard and Optional Forms for Contracting for 
Construction, Architect-Engineer Services, and Dismantling, Demolitation 
                       or Removal of Improvements



936.702  Forms for use in contracting for architect-engineer services.

    (a) The contracting officer shall also include the additional terms 
at 952.236-70 in Standard Form 252 item 6.



                Subpart 936.71--Inspection and Acceptance



936.7100  Scope of subpart.

    This subpart implements and supplements FAR Part 36 by prescribing 
the

[[Page 345]]

policies and requirements for inspection and acceptance under 
construction contracts.



936.7101  Construction contracts.

    (a) Inspection services may be performed by the architect-engineer 
responsible for the design. Inspection services may not be procured from 
a construction contractor with respect to its own work.
    (b) When one contractor is to inspect the work of another, the 
inspection contractor will be given written instructions defining its 
responsibilities and stating that it is not authorized to modify the 
terms and conditions of the contract, to direct additional work, to 
waive any requirements of the contract, or to settle any claim or 
dispute. Copies of the instructions will be given to the contractor who 
is to be inspected, with a request to acknowledge receipt on a copy to 
be returned to the contracting officer. In this manner, both contractors 
are on express notice of the authority and limitations of the authority 
of the inspecting contractor.



PART 937--SERVICE CONTRACTING--Table of Contents




             Subpart 937.70--Protective Services Contracting

937.7040  Contract clauses.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).



             Subpart 937.70--Protective Services Contracting

    Source:  58 FR 36151, July 6, 1993, unless otherwise noted.



937.7040  Contract clauses.

    The contracting officer shall insert the clause at 952.237-70 
entitled ``Collective bargaining agreements--protective services'' in 
all protective services solicitations and contracts involving DOE-owned 
facilities requiring continuity of services for public safety and 
national defense reasons. See also, 922.103-5, Contract clauses, which 
prescribes use of the clause at FAR 52.222-1, Notice to the Government 
of Labor Disputes.



PART 939--ACQUISITION OF FEDERAL INFORMATION PROCESSING RESOURCES BY CONTRACTING--Table of Contents




                      Subpart 939.0--Scope of Part

Sec.
939.001  Scope.

   Subpart 939.1--Federal Information Resources Management Regulation 
                             (FIRMR) System

939.101-5  Arrangement of part.
939.104-1  Deviations from the FIRMR.
939.106-3  Contracting authority and responsibilities.

                    Subparts 939.2-939.5  [Reserved]

                 Subpart 939.6--Competition Requirements

939.602-270  Outdated FIP equipment.

                    Subparts 939.7-939.9  [Reserved]

     Subpart 939.10--Specifications, Standards, and Other Purchase 
                              Descriptions

939.1003-70  Purchase of Energy Efficient Computers (Energy Star)

                   Subparts 939.11-939.43  [Reserved]

         Subpart 939.44--Subcontracting Policies and Procedures

939.4470  Contractor acquisitions of FIP resources.

                   Subparts 939.45-939.53  [Reserved]

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  60 FR 39873, Aug. 4, 1995, unless otherwise noted.



                      Subpart 939.0--Scope of Part



939.001  Scope.

    This part sets forth the policies that apply to the contracting for 
Federal Information Processing (FIP) resources by the Department of 
Energy (DOE).

[[Page 346]]



   Subpart 939.1--Federal Information Resources Management Regulation 
                             (FIRMR) System



939.101-5  Arrangement of part.

    For consistency with the FIRMR and the FAR, part 939 is arranged in 
54 subparts. Within each subpart, sections and subsections are numbered 
to correspond to like divisions of the FIRMR where the intent of the 
part 939 sections and subsections is to implement the FIRMR. Where the 
specific section or subsection is intended to supplement the FIRMR, or 
where specific FIRMR coverage does not exist, the section or subsection 
number is assigned a number of 70 or above.



939.104-1  Deviations from the FIRMR.

    (a) Only the General Services Administration (GSA) can authorize 
class deviations and individual deviations from the FIRMR. Within DOE, 
contracting officers shall submit requests for deviations from the FIRMR 
to the Headquarters Office of Clearance and Support for approval and 
subsequent processing with GSA.
    (b) Approval Requirements. The Head of the Contracting Activity 
(HCA), after coordination with local counsel, shall concur in requests 
for deviations prior to submission to the Office of Clearance and 
Support. The Procurement Executive shall approve all requests for 
deviations prior to submission of the request to GSA.



939.106-3  Contracting authority and responsibilities.

    (a) In instances where a specific acquisition delegation of 
procurement authority is not required under (FIRMR) 41 CFR 201-20.305-3, 
Specific Acquisition Delegations, each HCA may acquire FIP resources up 
to 50 percent of the regulatory delegation thresholds prescribed in 
(FIRMR) 41 CFR 201-20.305-1, Regulatory Delegations, unless different 
thresholds have been established either in the HCA's delegation of 
contracting authority, or in a specific agency delegation from GSA under 
(FIRMR) 41 CFR201-20.305-2, Specific Agency Delegations of Procurement 
Authority (DPA); or, in internal DOE guidance documents.
    (b) The contracting officer is responsible for ensuring compliance 
with all terms, conditions, and limitations imposed on DOE under a 
specific acquisition Delegation of Procurement Authority (DPA).
    (c) The contracting officer shall not award a contract, or a 
modification to an existing contract, when the value of the FIP 
resources portion of the award, including the value of any options, 
exceeds DOE's delegated FIP procurement authority redelegated to the HCA 
by the DSO. Where the anticipated award value of the FIP resources 
portion of the contract, or modification to the contract, exceeds DOE's 
delegated procurement authority, DOE shall obtain a revised delegation 
from GSA prior to award. Where the anticipated award value of the FIP 
resources portion of the contract, or modification to the contract, 
exceeds the HCA's redelegated procurement authority for that 
acquisition, the contracting officer shall have the redelegation 
revised, in accordance with internal DOE guidance documents, prior to 
award.



                     Subparts 939.2-939.5 [Reserved]



                 Subpart 939.6--Competition Requirements



939.602-270  Outdated FIP equipment.

    Solicitations and contracts for, or using, outdated FIP equipment 
shall be submitted to the Office of Clearance and Support for review and 
approval. The Office of Information Management shall review these 
documents and make the decision whether to allow the acquisition or use 
of outdated FIP equipment.



                    Subparts 939.7-939.9  [Reserved]



     Subpart 939.10--Specifications, Standards, and Other Purchase 
                              Descriptions



939.1003-70  Purchase of Energy Efficient Computers (Energy Star).

    Executive Order 12845, ``Purchase of Energy Efficient Computers by 
Federal Agencies,'' requires agencies to acquire microcomputers, 
including personal computers, monitors, and printers,

[[Page 347]]

that meet the ``Energy Star'' requirements established by the 
Environmental Protection Agency for energy efficiency. Solicitations for 
microcomputers and peripheral equipment, issued after October 21, 1993, 
are required to include a requirement that equipment meet the ``Energy 
Star'' standard, unless an exemption has been provided by the Head of 
the Contracting Activity as authorized under section 1(a) of Executive 
Order 12845.



                   Subparts 939.11-939.43  [Reserved]



         Subpart 939.44--Subcontracting Policies and Procedures



939.4470  Contractor acquisitions of FIP resources.

    (a) Management and operating (M&O) contracts. Except as provided in 
paragraph (c) of this section, M&O contractors and their subcontractors 
shall not be used to acquire FIP resources unrelated to the mission of 
the M&O contract either for sole use by DOE employees or employees of 
other DOE contractors, or for use by other Federal agencies or their 
contractors.
    (b) Other than M&O contracts. Where it has been determined that a 
contractor (other than an M&O contractor or its subcontractor) will 
acquire FIP resources either for sole use by DOE employees or for the 
furnishing of the FIP resources as government-furnished property under 
another contract, DOE will obtain any needed procurement authority from 
GSA prior to having the contractor acquire the FIP resources.
    (c) Consolidated contractor acquisitions. When common FIP resource 
requirements in support of DOE programs have been identified and it is 
anticipated that the consolidation of such requirements will promote 
cost or other efficiencies, the Designated Senior Official for 
Information Management may authorize an M&O contractor to acquire FIP 
resources for use by the following:
    (1) One or more other contractor(s) performing on-site at the same 
DOE-owned or -leased facility as the M&O contractor, or
    (2) Other M&O contractors.



                   Subparts 939.45-939.53  [Reserved]



PART 941--ACQUISITION OF UTILITY SERVICES--Table of Contents




                Subpart 941.2--Acquiring Utility Services

Sec.
941.201-70  DOE Directives.
941.201-71  Use of subcontracts.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  61 FR 41710, Aug. 9, 1996, unless otherwise noted.



                Subpart 941.2--Acquiring Utility Services



941.201-70  DOE Directives.

    Utility services (defined at FAR 41.101) shall be acquired in 
accordance with FAR part 41 and DOE Directives in subseries 4540 (Public 
Services).



941.201-71  Use of subcontracts.

    Utility services for the furnishing of electricity, gas (natural or 
manufactured), steam, water and/or sewerage at facilities owned or 
leased by DOE shall not be acquired under a subcontract arrangement, 
except as provided for at 48 CFR 970.0803 or if the prime contract is 
with a utility company.

[[Page 348]]



                    SUBCHAPTER G--CONTRACT MANAGEMENT





PART 942--CONTRACT ADMINISTRATION--Table of Contents




                   Subpart 942.7--Indirect Cost Rates

Sec.
942.704  Billing rates.
942.705-1  Contracting officer determination procedure.
942.705-3  Educational institutions.
942.705-4  State and local governments.
942.705-5  Nonprofit organizations other than educational and state and 
          local governments.

                  Subpart 942.8--Disallowance of Costs

942.803  Disallowing costs after incurrence.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12026, Mar. 28, 1984, unless otherwise noted.



                   Subpart 942.7--Indirect Cost Rates



942.704  Billing rates.

    (b) When the contracting officer or auditor responsible for 
establishing billing rates, in accordance with FAR 42.704, has not 
established such rates or such rates are not current for the performance 
periods (contractor FY) under contract, the DOE contracting officer 
responsible for administration of the contract shall establish an 
appropriate rate(s) for billing purposes. If the contractor holds more 
than one DOE contract covering that period of performance, the DOE 
office with the largest unliquidated obligations as of the beginning of 
that performance period shall take the lead in establishing the required 
billing rate for use on DOE contracts. Once appropriate billing rates 
are established by the responsible contracting officer designated by FAR 
42.704, such rates shall be adopted by the contracting officer and all 
billings and payments shall be retroactively revised to reflect the 
agreed upon rate(s).



942.705-1  Contracting officer determination procedure. (DOE coverage--paragraphs (a) and (b))

    (a)(3) The Department of Energy shall use the contracting officer 
determination procedure for all business units for which it shall be 
required to negotiate final indirect cost rates. A list of such business 
units is maintained by the Office of Policy, within the Headquarters 
procurement organization.
    (b)(1) Pursuant to FAR 52.216-7, Allowable Cost and Payment, 
contractors shall be requested to submit their final indirect cost rate 
proposals reflecting actual cost experience during the covered period to 
the cognizant contracting officer responsible for negotiating their 
final rates.
    The DOE negotiating official shall request all needed audit service 
in accordance with internal procedures.
[61 FR 41710, Aug. 9, 1996]



942.705-3  Educational institutions. (DOE coverage--paragraph (a))

    (a)(2) The negotiated rates established for the institutions cited 
in OMB Circular No. A-88 are distributed to the Cognizant DOE Office 
(CDO) assigned lead office responsibility for all DOE indirect cost 
matters relating to a particular contractor by the Office of Policy, 
within the Headquarters procurement organization.
[61 FR 41710, Aug. 9, 1996]



942.705-4  State and local governments.

    A list of cognizant agencies for State/local government 
organizations is periodically published in the Federal Register by the 
Office of Management and Budget (OMB). The responsible agencies are 
notified of such assignments. The current negotiated rates for State/
local government activities is distributed to each CDO by the Office of 
Policy, within the Headquarters procurement organization.
[61 FR 41710, Aug. 9, 1996]



942.705-5  Nonprofit organizations other than educational and state and local governments.

    OMB Circular A-122 establishes the rules for assigning cognizant 
agencies for the negotiation and approval of indirect cost rates. The 
Federal agency with the largest dollar value of awards

[[Page 349]]

(contracts plus federal financial assistance dollars) will be designated 
as the cognizant agency. There is no published list of assigned 
agencies. The Office of Policy, within the Headquarters procurement 
organization, distributes to each CDO the rates established by the 
cognizant agency.
[61 FR 41710, Aug. 9, 1996]



                  Subpart 942.8--Disallowance of Costs



942.803  Disallowing costs after incurrence.

    (a) Contracting officer receipt of vouchers. Vouchers and invoices 
submitted to DOE shall be submitted to the contracting officer or 
designee for review and approval for payment. If the examination of a 
voucher or invoice raises a question regarding the allowability of a 
cost submitted therein, the contracting officer, shall:
    (1) Hold informal discussion with the contractor as appropriate.
    (2) Issue a notice (letter, memo, etc.) to the contractor advising 
of cost disallowed or to be disallowed and advising the contractor that 
it may:
    (i) Submit a written claim as to why the cost should be reimbursed--
if in disagreement with the disallowance.
    (ii) File a claim under the disputes clause, which will be processed 
in accordance with disputes procedures in the event disagreements cannot 
be settled.
    (3) Process the voucher or invoice for payment and advise the 
finance office to deduct the disallowed cost when scheduling the voucher 
for payment.
    (c) Auditor reports and other sources of questioned costs. (1) From 
time to time reports are received from professional auditors that may 
question the allowability of an incurred cost. Such reports are received 
as the result of auditors, in their independent role under OMB Circular 
A-73 or their own charters, scheduling and conducting financial or 
compliance audits of government contracts or as the result of an 
independent request for auditor service, as discussed in 942.70 Audit 
Services.
    (2) When auditor reports or other notifications question cost or 
consider them unallowable, the contracting officer shall follow up such 
reports and resolve all such cost issues promptly by determining, 
through discussions with the contractor and/or auditor within six months 
of the audit report date, or date of receipt if a non-Federal audit. One 
of the following courses of action shall be pursued:
    (i) Accept and implement audit recommendations as submitted.
    (ii) Accept the principle of the audit recommendation but reject the 
cost questioned amount.
    (iii) Reject audit findings and recommendations.
    (3) When implementing the accepted course of action, the contracting 
officer shall--
    (i) Hold discussions with the auditor and contractor as appropriate.
    (ii) Issue a notice in writing advising the contractor of the 
government's intent to disallow the cost questioned, if the contracting 
officer agrees with the auditor concerning the questioned costs.
    (iii) Negotiate a mutual settlement of questioned costs if they are 
agreed with in principle but there is a difference of opinion as to a 
proper amount.
    (iv) Negotiate a mutual settlement of questioned costs if the 
auditor recommendations are acceptable to the contracting officer but 
the contractor does not accept the finding or disallowance.
    (v) Issue a final decision of the contracting officer disallowing 
the questionable cost where differences cannot be resolved, advising of 
the contractor's right to appeal the decision, and advising the 
procedure to be followed if it is decided to make such an appeal.
    (vi) Initiate immediate recoupment actions for all disallowed cost 
owed the government by:
    (A) Requesting the contractor to provide a credit adjustment 
(offset) against amounts billed the government on the next or future 
invoice(s) if such shall be submitted under a contract for which the 
disallowed cost applies.
    (B) Deducting (offset) the disallowed cost from the next or future 
invoice(s) submitted under the contract; if the contractor provides no 
adjustment

[[Page 350]]

under the contract for which the disallowed cost applies; provided such 
reduction is deemed appropriate.
    (C) Advising the contractor that a refund shall be directly payable 
to the government in situations where there are insufficient payments 
owed by the government to effect recovery via (A) or (B) above or an 
offset is otherwise inappropriate.
    (vii) Promptly notify the appropriate finance office of refunds 
directly payable to the government to ensure proper billing and follow-
up action for collection.
[49 FR 12026, Mar. 28, 1984, as amended at 59 FR 9107, Feb. 25, 1994]



PART 944--SUBCONTRACTING POLICIES AND PROCEDURES--Table of Contents




         Subpart 944.3--Contractors' Purchasing Systems Reviews

Sec.
944.302  Requirements.
944.304  Surveillance.
944.305  Granting, withholding, or withdrawing approval.
944.305-1  Responsibilities.
944.307  Reports.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12031, Mar. 28, 1984, unless otherwise noted.



         Subpart 944.3--Contractors' Purchasing Systems Reviews



944.302  Requirements.

    (a) The Heads of Contracting Activities shall consider whether the 
best interest of DOE would be served by the initiation of a Contractor 
Purchasing System Review (CPSR) for those contractors whose sales to DOE 
are expected to exceed $5,000,000 during the next 12 months and for 
which DOE is the cognizant Government agency for CPSR purposes. In 
exceptional circumstances, consideration of a CPSR may be warranted for 
contractors with sales to DOE of less than $5,000,000. When considering 
the initiation of a CPSR, such a review should not be conducted if the 
extent of the contractor's subcontracting program does not appear to 
justify the review.
    (b) DOE contracting officers, or designees, will conduct CPSRs of 
DOE cognizant contractors. Other Federal Agencies/Departments may be 
requested to conduct CPSRs, as appropriate, for other than DOE cognizant 
contractors. DOE contracting officers shall normally recognize other 
Federal Agency/Department approvals of contractors' purchasing systems 
within the limitation identified by approving officials of such 
agencies.
    (c) Initial, subsequent, and follow-up review teams should include 
appropriate representatives from DOE field offices; other Federal Agency 
participation may be additionally requested as appropriate. Generally, 
team composition should not consist exclusively of those who have a day-
to-day relationship with the contractor regarding subcontract consent or 
approval.
    (d) The Procurement Executive is responsible for the overall conduct 
of the DOE CPSR program.
[49 FR 12031, Mar. 28, 1984, as amended at 59 FR 9107, Feb. 25, 1994]



944.304  Surveillance.

    (b) The surveillance plan required by FAR 44.304(b) shall be 
approved by the Head of the Contracting Activity.



944.305  Granting, withholding, or withdrawing approval.



944.305-1  Responsibilities.

    (a) Team findings and recommendations contained in a CPSR Report 
shall be approved by the Head of the Contracting Activity before the 
contracting officer makes a determination to continue, grant, withhold, 
or withdraw approval.
[49 FR 12031, Mar. 28, 1984, as amended at 59 FR 9107, Feb. 25, 1994]



944.307  Reports.

    (b) Copies of CPSR reports; notifications granting, continuing, 
withholding, or withdrawing approval of a contractor's purchasing 
system; copies of recommendations for improvement of an approved system; 
notifications (or contract modifications) altering the subcontract 
consent dollar thresholds; and information received from the contractor 
pursuant to FAR 44.305-3(b) shall be transmitted to the Director, Office 
of Contractor Management and

[[Page 351]]

Administration, within the Headquarters procurement organization.
[49 FR 12031, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 59 
FR 9107, Feb. 25, 1994]



PART 945--GOVERNMENT PROPERTY--Table of Contents




Sec.
945.000  Scope of part.

                         Subpart 945.1--General

945.101  Definitions.
945.102-70  Reporting of contractor-held property.
945.102-71  Maintenance of records.

       Subpart 945.3--Providing Government Property to Contractors

945.303-1  Policy.

     Subpart 945.4--Contractor Use and Rental of Government Property

945.407  Non-Government use of plant equipment.

 Subpart 945.5--Management of Government Property in the Possession of 
                               Contractors

945.505-11  Records of transportation and installation costs of plant 
          equipment.
945.506  Identification.
945.570-2  Acquisition of motor vehicles.
945.570-7  Disposition of motor vehicles.
945.570-8  Reporting motor vehicle data.

  Subpart 945.6--Reporting, Redistribution, and Disposal of Contractor 
                                Inventory

945.601  Definitions.
945.603  Disposal methods.
945.603-70  Plant clearance function.
945.603-71  Disposal of radioactively contaminated personal property.
945.607-2  Recovering precious metals.
945.608-2  Standard screening.
945.608-3  Agency screening.
945.608-4  Limited screening.
945.608-5  Special items screening.
945.608-6  Waiver of screening requirements.
945.610-4  Contractor inventory in foreign countries.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12032, Mar. 28, 1984, unless otherwise noted.



945.000  Scope of part.

    This part and FAR Part 45 are not applicable to the management of 
property by operating and management contractors. In addition, the 
policies and procedures contained in FAR Part 45 governing the 
management, control, reporting, and disposal of special test equipment 
and special tooling are not followed by the DOE.



                         Subpart 945.1--General



945.101  Definitions.

    Personal property, as used in this part, means property of any kind 
or interest therein, except real property; records of the Federal 
Government; and nuclear and special source materials, atomic weapons, 
and by-product materials.
    Capital equipment, as used in this part, means personal property 
items having a unit acquisition cost of $5,000 or more and an 
anticipated service life in excess of two years, regardless of type of 
funding, and having the potential for maintaining their integrity as 
capital items; i.e., not expendable due to use.
[54 FR 27647, June 30, 1989]



945.102-70  Reporting of contractor-held property.

    Within 30 days after the end of each fiscal year, the Head of the 
Contracting Activity shall report the following information to the 
Director, Office of Property Management, within the Headquarters 
procurement organization.
    (a) Name and address of each contractor with DOE property in their 
possession, or in the possession of their subcontractors (do not include 
grantees, cooperative agreements, interagency agreements, or agreements 
with state or local governments).
    (b) Contract number of each DOE contract with Government property.
    (c) Date contractor's property management system was approved and by 
whom (DOE office, Defense Contract Management Command, or the Office of 
Naval Research).
    (d) Date of most current appraisal of contractor's property 
management system, who conducted the appraisal, and status of the system 
(satisfactory or unsatisfactory).

[[Page 352]]

    (e) Total dollar value of DOE property as reported on last 
semiannual asset report (including date of report), for each DOE 
contract administered by the contracting activity.
[49 FR 12032, Mar. 28, 1984, as amended at 59 FR 9107, Feb. 25, 1994]



945.102-71  Maintenance of records.

    The contracting activity shall maintain records of approvals and 
reviews of contractors' property management systems, the dollar value of 
DOE property as reported on the most recent semiannual financial report, 
and records on property administration delegations to other Government 
agencies.



       Subpart 945.3--Providing Government Property to Contractors



945.303-1  Policy.

    The DOE has established specific policies concerning special nuclear 
material requirements needed under DOE contracts for fabricating end 
items using special nuclear material, and for conversion or scrap 
recovery of special nuclear material. Special nuclear material means 
uranium enriched in the isotopes U233, and U235, and/or plutonium other 
than PU238. The policies to be followed are:
    (a) Special nuclear material will be furnished by the DOE for fixed-
price contracts and subcontracts, at any tier, which call for the 
production of special nuclear products, including fabrication and 
conversion, for Government use. (The contractor or subcontractor must 
have the appropriate license or licenses to receive the special nuclear 
material. The Nuclear Regulatory Commission is the licensing agency.)
    (b) Contracts and subcontracts for fabrication of end items using 
special nuclear material generally shall be of the fixed-price type. 
Cost-type contracts or subcontracts for fabrication shall be used only 
with the approval of the Head of the Contracting Activity. This approval 
authority shall not be further delegated.
    (c) Contracts and subcontracts for conversion or scrap recovery of 
special nuclear material shall be of a fixed-price type, except as 
otherwise approved by the Head of the Contracting Activity.
[49 FR 12032, Mar. 28, 1984, as amended at 59 FR 9108, Feb. 25, 1994]



     Subpart 945.4--Contractor Use and Rental of Government Property



945.407  Non-Government use of plant equipment.

    The type of plant equipment and dollar threshold for non-Government 
use of DOE plant equipment will be determined by the Head of the 
Contracting Activity which awarded the contract. Approval of the Head of 
the Contracting Activity is required to authorize non-Government use 
exceeding 25% of operational use.



 Subpart 945.5--Management of Government Property in the Possession of 
                               Contractors



945.505-11  Records of transportation and installation costs of plant equipment.

    The requirements of FAR 45.505-11 apply to plant equipment having a 
unit cost of $1,000 or more.



945.506  Identification.

    The requirements of FAR 45.506 apply to Government property having a 
unit cost of $1,000 or more.



945.570-2  Acquisition of motor vehicles.

    (a) The GSA Interagency Fleet Management System (GSA-IFMS) is the 
first source of supply for providing motor vehicles to contractors; 
however, contracting officer approval is required for contractors to 
utilize this service.
    (b) Prior approval of GSA must be obtained before--
    (1) Fixed-price contractors can use the GSA-IFMS;
    (2) DOE-owned motor vehicles can be furnished to any contractor in 
an area served by a GSA-IFMS; and
    (3) A contractor can commercially lease a motor vehicle for more 
than 60 days.

[[Page 353]]

    (c) GSA has the responsibility for acquisition of motor vehicles for 
Government agencies. All requisitions (GSA Form 1781) shall be processed 
in accordance with 41 CFR 101-26.501.
    (d) Contractors shall submit all motor vehicle requirements to the 
contracting officer for approval.
    (e) The acquisition of sedans and station wagons is limited to 
small, subcompact, and compact vehicles which meet Government fuel 
economy standards. The acquisition of light trucks is limited to those 
vehicles which meet the current fuel economy standards set by Executive 
Orders 12003 and 12375.
    (f) Cost reimbursement contractors may be authorized by the 
contracting officer to utilize GSA Federal Supply Schedule 751, Motor 
Vehicle Rental, for short term rentals not to exceed 60 days, and are 
required to utilize available GSA consolidated leasing programs for long 
term (60 continuous days or longer) commercial leasing of passenger 
vehicles and light trucks.
    (g) The Office of Property Management, within the Headquarters 
procurement organization, shall certify all requisitions prior to 
submittal to GSA for the following:
    (1) The acquisition of sedans and station wagons.
    (2) The lease (60 continuous days or longer) of any passenger 
automobile.
    (3) The acquisition or lease (60 continuous days or longer) of light 
trucks less than 8,500 GVWR.
    (h) Purchase requisitions for other motor vehicles may be submitted 
directly to GSA when approved by the contracting officer.
    (i) Contractors shall thoroughly examine motor vehicles acquired 
under a GSA contract for defects. Any defect shall be reported promptly 
to GSA, and repairs shall be made under terms of the warranty.
[49 FR 12032, Mar. 28, 1984, as amended at 59 FR 9108, Feb. 25, 1994]



945.570-7  Disposition of motor vehicles.

    (a) The contractor shall dispose of DOE-owned motor vehicles as 
directed by the contracting officer.
    (b) DOE-owned motor vehicles may be disposed of as exchange/sale 
items when directed by the contracting officer; however, a designated 
DOE official must execute the Title Transfer forms.



945.570-8  Reporting motor vehicle data.

    (a) Contractors conducting motor vehicle operations shall forward 
annually (on or before December 1) to the contracting officer their plan 
for acquisition of motor vehicles for the next fiscal year for review, 
approval and submittal to DOE Headquarters. This plan shall conform to 
the fuel efficiency standards for motor vehicles for the applicable 
fiscal year, as established by Executive Orders 12003 and 12375 and as 
implemented by GSA and current DOE directives. Additional guidance for 
the preparation of the plan will be issued by the contracting officer, 
as required.
    (b) Contractors operating DOE-owned and/or commercially leased (for 
60 continuous days or longer) motor vehicles shall prepare and submit 
the following annual year-end reports to the contracting officer:
    (1) DOE Report of Motor Vehicle Data (passenger vehicles).
    (2) DOE Report of Truck Data.
[49 FR 12032, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984]



  Subpart 945.6--Reporting, Redistribution, and Disposal of Contractor 
                                Inventory



945.601  Definitions.

    Personal property (See 945.101).



945.603  Disposal methods.



945.603-70  Plant clearance function.

    If the plant clearance function has not been formally delegated to 
another Federal agency, the contracting officer shall assume all 
responsibilities of the plant clearance officer identified in FAR 
Subpart 45.6.



945.603-71  Disposal of radioactively contaminated personal property.

    Special procedures regarding the disposal of radioactively 
contaminated property may be found at 41 CFR 109-45.50.

[[Page 354]]



945.607-2  Recovering precious metals.

    (b) Contractors generating contractor inventory containing precious 
metals shall identify and promptly report such items to the contracting 
officer for review, approval and reporting to the DOE precious metals 
pool. This includes all precious metals in any form, including shapes, 
scrap or radioactively contaminated, except for silver. Only high grade 
nonradioactively contaminated silver should be reported to the precious 
metals pool. The Oak Ridge Operations Office is responsible for 
maintaining the DOE pool. Precious metals scrap will be reported to the 
DOE precious metals pool, operated by Martin Marietta Energy Systems, 
M.S. 8207, P.O. Box 2009, Oak Ridge, TN 37831.
[54 FR 27648, June 30, 1989, as amended at 59 FR 9108, Feb. 25, 1994]



945.608-2  Standard screening.

    (b)(1) Prior to reporting excess property to GSA, all reportable 
property, as identified in Federal Property Management Regulations 41 
CFR 101-43.4801, shall be reported to the contracting office. The 
contracting office shall transmit this information via terminal 
processing or hard copy to DOE Headquarters for centralized screening in 
the DOE Reportable Excess Automated Property System (REAPS). Agency 
screening will begin when the item is first included in the REAPS 
monthly catalog and will end upon the issuance of the following monthly 
catalog.
    (i) REAPS requires the inclusion of a five character address code 
which identifies the reporting contractor. The address code will be 
assigned by DOE Headquarters upon receipt of a completed Address 
Notification form for the contractor or DOE office reporting the 
property as excess.
    (ii) Excess screening documents and Address Notification forms shall 
be submitted to the Office of Contractor Management and Administration, 
within the Headquarters procurement organization.
[49 FR 12032, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 59 
FR 9108, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



945.608-3  Agency screening.

    Items shall be reported to the contracting office and should be 
screened informally within the contracting office's complex of 
contractors and with other known users of the property at other DOE 
locations.



945.608-4  Limited screening.

    (a) Prior to reporting to GSA, all nonreportable property, excluding 
scrap and salvage, shall be reported to the contracting office for a 15 
day informal screening within the contracting office's complex of 
contractors and other appropriate DOE field locations.



945.608-5  Special items screening.

    Prior to reporting to GSA, that property in FAR 45.608-5 (a), (b), 
and (d) shall be reported and screened within DOE in accordance with 
945.608-2 and 945.608-3.
    (c) Printing equipment. All printing equipment excess to 
requirements shall be reported to the Office of Administrative Services, 
Headquarters.



945.608-6  Waiver of screening requirements.

    (a) The Director Office of Property Management, within the 
Headquarters procurement organization, is the designee who may authorize 
exceptions from screening requirements in accordance with the provisions 
of FAR 45.608-6.
    (b) A request to the Director of the Office of Property Management, 
within the Headquarters procurement organization for the waiver of 
screening requirements must be submitted by the HCA with a justification 
setting forth the compelling circumstances warranting the exception.
[54 FR 27648, June 30, 1989, as amended at 59 FR 9108, Feb. 25, 1994]



945.610-4  Contractor inventory in foreign countries.

    Contractor inventory located in foreign countries will be utilized 
and disposed of in accordance with DOE-PMR 41 CFR 109-43.5, and 45.51.
[49 FR 12032, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984]

[[Page 355]]



PART 947--TRANSPORTATION--Table of Contents




    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12038, Mar. 28, 1984, unless otherwise noted.



        Subpart 947.5--Ocean Transportation by U.S. Flag Vessels



947.506  Procedures.

    For contract awards involving foreign suppliers which will 
necessitate ocean transportation, a copy of the award document is to be 
furnished to the Maritime Administration at the following address: 
Inter-Agency Liaison, Division of National Cargo, Office of Market 
Development, Maritime Administration, 400 7th Street, SW., Washington, 
DC 20590



PART 949--TERMINATION OF CONTRACTS--Table of Contents




                    Subpart 949.1--General Principles

Sec.
949.101  Authorities and responsibilities.
949.106  Fraud or other criminal conduct.
949.111  Review of proposed settlements.

               Subpart 949.5--Contract Termination Clauses

949.501  General.
949.505  Other termination clauses.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12038, Mar. 28, 1984, unless otherwise noted.



                    Subpart 949.1--General Principles



949.101  Authorities and responsibilities.

    The Procurement Executive shall be notified prior to taking any 
action to terminate (a) contracts for the operation of Government-owned 
facilities, (b) any prime contract or subcontract in excess of $10 
million, and (c) any contract the termination of which is likely to 
provoke unusual interest.



949.106  Fraud or other criminal conduct.

    Any evidence of fraud or other criminal conduct in connection with 
the settlement of a contract termination shall be reported in accordance 
with 909.406.



949.111  Review of proposed settlements.

    (a) The Heads of Contracting Activities shall establish settlement 
review boards for the review of each termination settlement or 
determination of amount due under the termination clause of a contract 
or approval or ratification of a subcontract settlement when the action 
involves $50,000 or more.
    (b) Settlement review boards may be established for actions below 
$50,000 when considered desirable by the Head of the Contracting 
Activity or when specifically requested by the contracting officer.
    (c) Proposed settlement agreements or determinations in excess of 
contractual authority of the Heads of Contracting Activities will be 
transmitted to the Procurement Executive for review and approval.
    (d) Contracting officers shall not conclude proposed settlement or 
determinations until the approvals required by this subsection have been 
obtained.
[49 FR 12038, Mar. 28, 1984, as amended at 59 FR 9108, Feb. 25, 1994]



               Subpart 949.5--Contract Termination Clauses



949.501  General.

    The standard clauses set forth in FAR Subpart 49.5 are applicable as 
prescribed subject to the cost principles referenced in the various 
termination articles shall be in accordance with part 931.
[49 FR 12038, Mar. 28, 1984, as amended at 59 FR 9108, Feb. 25, 1994]



949.505  Other termination clauses.

    (f) The clause at 952.249-70 is suggested for use in cost-plus-
fixed-fee Architect-Engineer contracts.



PART 950--EXTRAORDINARY CONTRACTUAL ACTIONS--Table of Contents




                         Subpart 950.1--General

Sec.
950.104  Reports.

[[Page 356]]

       Subpart 950.70--Nuclear Indemnification of DOE Contractors

950.7000  Scope of subpart.
950.7001  General policy.
950.7002  Definitions.
950.7003  Nuclear hazards indemnity.
950.7004-950.7005  [Reserved]
950.7006  Statutory nuclear hazards indemnity agreement.
950.7007-950.7008  [Reserved]
950.7009  Fees.
950.7010  Financial protection requirements.

          Subpart 950.71--General Contract Authority Indemnity

950.7101  Applicability.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12039, Mar. 28, 1984, unless otherwise noted.



                         Subpart 950.1--General



950.104  Reports.

    The information required by FAR 50.104(b) for all actions taken 
under the extraordinary emergency authority shall be submitted to the 
Director, Office of Clearance and Support, within the Headquarters 
procurement organization no later than 30 days after the date of 
completion of processing the action. In the event no actions were taken 
under Pub. L. 85-804 during the preceding calendar year, a negative 
report should be submitted to the Director, Office of Clearance and 
Support, within the Headquarters procurement organization no later than 
January 20 of each year.
[49 FR 12039, Mar. 28, 1984, as amended at 59 FR 9108, Feb. 25, 1994];



       Subpart 950.70--Nuclear Indemnification of DOE Contractors



950.7000  Scope of subpart.

    The General Services Administration (GSA) and, in some cases, the 
Department of Defense (DOD) Military Traffic Management Command 
negotiate agreements with commercial organizations to provide certain 
discounts to contractors traveling under Government cost-reimbursable 
contracts. In the case of discount air fares and hotel/motel room rates, 
the GSA has established agreements with certain airlines and thousands 
of hotels/motels to extend discounts which were previously only 
available to Federal employees on official travel status. DOD has 
negotiated agreements with car rental companies for special rates with 
unlimited mileage which were also to be used by only Federal employees 
on official Government business. GSA Federal Property Management 
Regulations (FPMRs) make these three travel discounts available to 
Government cost-reimbursable contractors at the option of the vendor.
[60 FR 30005, June 7, 1995]



951.7001  General policy.

    Contracting officers will encourage DOE cost-reimbursable 
contractors (CRCs) to use Government travel discounts to the maximum 
extent practicable in accordance with contractual terms and conditions. 
Vendors providing the service may require that Government contractor 
employees furnish a letter of identification signed by the authorizing 
contracting officer. Contracting officers shall provide CRCs with a 
``Standard Letter of Identification'' when appropriate to do so. An 
example of a ``Standard Letter of Identification'' is at 952.251-70(e).
[60 FR 30005, June 7, 1995]



950.7002  Definitions.

    DOE contractor means any DOE prime contractor, including any agency 
of the Federal Government with which DOE has entered into an interagency 
agreement.
    Nuclear incident means any occurrence, including an extraordinary 
nuclear occurrence, within the United States causing, within or outside 
the United States, bodily injury, sickness, disease, or death, or loss 
of or damage to property, or loss of use of property, arising out of or 
resulting from the radioactive, toxic, explosive, or other hazardous 
properties of source, special nuclear, or byproduct material. The term 
includes any such occurrence outside the United States if such 
occurrence involves source, special nuclear, or byproduct material owned 
by, and used by or under contract with, the United States.
    Person indemnified means:

[[Page 357]]

    (1) With respect to a nuclear incident occurring within the United 
States or outside the United States as the term is defined above and 
with respect to any nuclear incident in connection with the design, 
development, construction, operation, repair, maintenance, or use of the 
nuclear ship Savannah, the person with whom an indemnity agreement is 
executed or who is required to maintain financial protection, and any 
other person who may be liable for public liability; or
    (2) With respect to any other nuclear incident occurring outside the 
United States, the person with whom an indemnity agreement is executed 
and any other person who may be liable for public liability by reason of 
his activities under any contract with the Secretary of Energy or any 
project to which indemnification under the provisions of section 170d. 
of the Atomic Energy Act of 1954, as amended, has been extended or under 
any subcontract, purchase order, or other agreement, or any tier under 
any such contract or project.
    Public liability means any legal liability arising out of or 
resulting from a nuclear incident or precautionary evacuation (including 
all reasonable additional costs incurred by a State, or a political 
subdivision of a State, in the course of responding to a nuclear 
incident or precautionary evacuation), except: (1) Claims under State or 
Federal workmen's compensation acts of employees of persons indemnified 
who are employed at the site of and in connection with the activity 
where the nuclear incident occurs; (2) claims arising out of an act of 
war; and (3) whenever used in subsections a., c., and k. of section 170 
of the Atomic Energy Act of 1954, as amended, claims for loss of, or 
damage to, or loss of use of property which is located at the site of 
and used in connection with the licensed activity where the nuclear 
incident occurs. Public liability also includes damage to property of 
persons indemnified: Provided, that such property is covered under the 
terms of the financial protection required, except property which is 
located at the site of and used in connection with the activity where 
the nuclear incident occurs.
[49 FR 12039, Mar. 28, 1984, as amended at 50 FR 12185, Mar. 27, 1985; 
56 FR 57827, Nov. 14, 1991]



950.7003  Nuclear hazards indemnity.

    (a) Section 170d. of the Atomic Energy Act, as amended, requires DOE 
``to enter into agreements of indemnification with any person who may 
conduct activities under a contract with (DOE) that involve the risk of 
public liability * * *.'' However, DOE contractors whose activities are 
already subject to indemnification by the Nuclear Regulatory Commission 
are not eligible for such statutory indemnity. See 950.7006 below.
    (b) The Heads of Contracting Activities shall assure that contracts 
subject to this requirement contain the appropriate nuclear hazards 
indemnity provisions.
[56 FR 57828, Nov. 14, 1991, as amended at 59 FR 9108, Feb. 25, 1994]



950.7004-950.7005  [Reserved]



950.7006  Statutory nuclear hazards indemnity agreement.

    (a) The contract clause contained in 952.250-70 shall be 
incorporated in all contracts in which the contractor is under risk of 
public liability for a nuclear incident or precautionary evacuation 
arising out of or in connection with the contract work, including such 
events caused by a product delivered to a DOE-owned facility for use by 
DOE or its contractors. The clause at 952.250-70 shall be included in 
contracts with architect-engineer contractors for the design of a DOE 
facility, the construction or operation of which may involve the risk of 
public liability for a nuclear incident or a precautionary evacuation.
    (b) However, this clause shall not be included in contracts in which 
the contractor is subject to Nuclear Regulatory Commission (NRC) 
financial protection requirements under section 170b. of the Act or NRC 
agreements of indemnification under section 170c. or k. of the Act for 
activities to be performed under the contract.
[56 FR 57828, Nov. 14, 1991, as amended at 59 FR 9108, Feb. 25, 1994]

[[Page 358]]



950.7007-950.7008  [Reserved]



950.7009  Fees.

    No fee will be charged a DOE contractor for a statutory nuclear 
hazards indemnity agreement.
[49 FR 12039, Mar. 28, 1984, as amended at 56 FR 57828, Nov. 14, 1991]



950.7010  Financial protection requirements.

    DOE contractors with whom statutory nuclear hazards indemnity 
agreements under the authority of section 170d. of the Atomic Energy Act 
of 1954, as amended, are executed will not normally be required or 
permitted to furnish financial protection by purchase of insurance to 
cover public liability for nuclear incidents. However, if authorized by 
the DOE Headquarters office having responsibility for contractor 
casualty insurance programs, DOE contractors may be (a) permitted to 
furnish financial protection to themselves or (b) permitted to continue 
to carry such insurance at cost to the Government if they currently 
maintain insurance for such liability.
[56 FR 57828, Nov. 14, 1991]



          Subpart 950.71--General Contract Authority Indemnity



950.7101  Applicability.

    (a) The DOE also has general contract authority to enter into 
indemnity agreements with its contractors. Under such authority a 
certain measure of protection is extended to the DOE contractor against 
risk of liability, but the assumption of liability by DOE will be 
expressly subject to the availability of appropriated funds. Prior to 
enactment of section 170 of the Atomic Energy Act 1954, as amended, this 
authority was exercised in a number of Atomic Energy Commission 
contracts and this type of indemnification remains in some DOE 
contracts.
    (b) It is the policy of the DOE, subsequent to the enactment of 
section 170, to restrict indemnity agreements with DOE contractors, with 
respect to protection against public liability for a nuclear incident, 
to the statutory indemnity provided under section 170. However, it is 
recognized that circumstances may exist under which a DOE contractor may 
be exposed to a risk of public liability for a nuclear occurrence which 
would not be covered by the statutory indemnity.
    (c) While it is normally DOE policy to require its non-management 
and operating contractors to obtain insurance coverage against public 
liability for nonnuclear risks, there may be circumstances in which a 
contractual indemnity may be warranted to protect a DOE non-management 
and operating contractor against liability for uninsured nonnuclear 
risks.
    (d) If circumstances as mentioned in paragraph (b) or (c) of this 
section do arise, it shall be the responsibility of the Heads of 
Contracting Activities to submit to the Head of the Agency or designee 
for review and decision, all pertinent information concerning the need 
for, or desirability of, providing a general authority indemnity to a 
DOE contractor.
    (e) Where the indemnified risk is nonnuclear, the amount of general 
authority indemnity extended to a fixed-price contractor should normally 
have a maximum obligation equivalent to the amount of insurance that the 
contractor usually carries to cover such risks in its other commercial 
operations or, if the risk involved is dissimilar to those normally 
encountered by the contractor, the amount that it otherwise would have 
reasonably procured to insure this contract risk.
    (f) In the event that a DOE contractor has been extended both a 
statutory indemnity and a general authority indemnity, the general 
authority indemnity will not apply to the extent that the statutory 
indemnity applies.
    (g) The provisions of this subsection do not restrict or affect the 
policy of DOE to pay its cost-reimbursement type contractors for the 
allowable cost of losses and expenses incurred in the performance of the 
contact work, within the maximum amount of the contract obligation.
[49 FR 12039, Mar. 28, 1984, as amended at 56 FR 28102, June 19, 1991. 
Redesignated and amended at 56 FR 57828, Nov. 14, 1991; 59 FR 9108, Feb. 
25, 1994; 61 FR 21977, May 13, 1996; 62 FR 34861, June 27, 1997]

[[Page 359]]



PART 951--USE OF GOVERNMENT SOURCES BY CONTRACTORS--Table of Contents




       Subpart 951.1--Contractor Use of Government Supply Sources

Sec.
951.101  Policy.
951.102  Authorization to use Government supply sources.
951.103  Ordering from Government supply sources.

          Subpart 951.70--Contractor Employee Travel Discounts

951.7002  Responsibilities.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12042, Mar. 28, 1984, unless otherwise noted.



       Subpart 951.1--Contractor Use of Government Supply Sources



951.101  Policy.

    (a) It is DOE policy that contractors performing under cost-
reimbursement contracts should meet their requirements from Government 
sources of supply when these sources are available to them, and if it is 
economically advantageous or otherwise in the best interest of the 
Government.



951.102  Authorization to use Government supply sources.

    (a) The Head of the Contracting Activity may authorize contractors 
performing under cost-reimbursement contracts and subcontractors 
performing under cost-reimbursement subcontracts, where all higher tier 
contracts and subcontracts are cost-type, to use Government supply 
sources in accordance with the requirements and procedures in FAR Part 
51, DOE PMR 41 CFR 109-26, and any necessary approval from the agency 
involved. This authority may be redelegated to the level of contracting 
officer. Direct acquisition by the DOE, rather than by a contractor 
under cost-reimbursement contracts, shall be required where deemed 
necessary by the Head of the Contracting Activity in order to carry out 
special requirements of appropriation acts or other applicable laws 
relating to particular items.
    (c)(1) The DOE central point of contact for the assignment, 
correction, or deletion of FEDSTRIP activity address codes is the Office 
of Property Management, within the Headquarters procurement 
organization.
    (e)(4)(iii) Materials, supplies, and equipment acquired from 
Government sources of supply under the procedures described herein must 
be used exclusively in connection with Government work, except as 
otherwise authorized by the Head of the Contracting Activity.
[49 FR 12042, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 59 
FR 9108, Feb. 25, 1994]



951.103  Ordering from Government supply sources.

    (b) The Procurement Executive shall be informed of instances in 
which GSA sources of supply are not used because of the quality of the 
items available from GSA or when a Federal Supply Schedule contractor 
refuses to honor an order.



          Subpart 951.70--Contractor Employee Travel Discounts

    Source:  54 FR 17736, Apr. 25, 1989, unless otherwise noted.



951.7002  Responsibilities.

    Contracting officers will include in all cost-reimbursable 
solicitations and resulting contracts, or contract modifications, the 
provision or clause, as applicable, at 952.251-70 when significant costs 
involving travel by air carrier, ground transportation by rental car and 
lodging at a hotel or motel will be required in connection with the 
performance of the contract. Contracting officers may furnish Government 
contractors with the identification letter for presentation to contract 
airline, hotel/motel or car rental firm (see 951.7001 above), depending 
upon the requirements of the vendor.

[[Page 360]]



                     SUBCHAPTER H--CLAUSES AND FORMS





PART 952--SOLICITATION PROVISIONS AND CONTRACT CLAUSES--Table of Contents




                         Subpart 952.0--General

Sec.
952.000  Scope of part.
952.001  General policy.

              Subpart 952.2--Text of Provisions and Clauses

952.202  Clauses related to definitions.
952.202-1  Definitions.
952.204  Clauses related to administrative matters.
952.204-2  Security requirements.
952.204-70  Classification.
952.204-71  Sensitive foreign nations controls.
952.204-72  Disclosure of information.
952.204-73  Foreign ownership, control, or influence over contractor 
          (Representation).
952.204-74  Foreign ownership, control, or influence over contractor.
952.208  Clauses related to required sources of supply.
952.208-7  Tagging of leased vehicles.
952.208-70  Printing.
952.209  Clauses related to contractor's qualifications.
952.209-8  Organizational Conflicts of Interest-Disclosure.
952.209-71  [Reserved]
952.209-72  Organizational conflicts of interest.
952.211  Clauses related to contract delivery or performance.
952.211-70  Priorities and allocations for energy programs 
          (solicitations).
952.211-71  Priorities and allocations for energy programs (contracts).
952.211-72  [Reserved]
952.211-73  [Reserved]
952.216  Clauses related to types of contracts.
952.216-7  Allowable cost and payment.
952.216-15  Predetermined indirect cost rates.
952.217-70  Acquisition of real property.
952.222-70  Whistleblower protection for contractor employees.
952.223  Clauses related to environment, conservation, and occupational 
          safety.
952.223-71  Integration of environment, safety, and health into work 
          planning and execution.
952.223-72  Radiation protection and nuclear criticality.
952.223-73  [Reserved]
952.223-74  [Reserved]
952.223-75  Preservation of individual occupational radiation exposure 
          records.
952.224-70  Paperwork Reduction Act.
952.225-70  Subcontracting for nuclear hot cell services.
952.226-70  Subcontracting goals under section 3021(a) of the Energy 
          Policy Act of 1992.
952.226-71  Utilization of Energy Policy Act target entities.
952.226-72  Energy Policy Act subcontracting goals and reporting 
          requirements.
952.226-73  Energy Policy Act target group certification.
952.226-74  Displaced employee hiring preference.
952.227  Provisions and clauses related to patents, technical data and 
          copyrights.
952.227-9  Refund of royalties.
952.227-11  Patent rights--retention by the contractor (short form).
952.227-13  Patent rights--acquisition by the Government.
952.227-70--952.227-72  [Reserved]
952.227-73  Additional technical data requirements.
952.227-74  [Reserved]
952.227-75  Rights in technical data--long form.
952.227-76  Rights in data--special works.
952.227-77  Rights in technical data clause--short form.
952.227-78  Rights in technical data--facility.
952.227-79  Limited rights in proprietary data.
952.227-82  Rights to proposal data.
952.227-83  Rights in technical data solicitation representation.
952.227-84  Notice of right to request patent waiver.
952.231-70  Date of incurrence of cost.
952.233-2  Service of protest.
952.233-4  Notice of protest file availability.
952.233-5  Agency protest review.
952.235-70  Key personnel.
952.236  Construction and architect-engineer contracts.
952.236-70  Administrative terms for architect-engineer contracts.
952.236-71  Inspection in architect-engineer contracts.
952.236-72  Nonrefundable fee for plans and specifications.
952.237-70  Collective bargaining agreements--protective services.
952.245  Clauses related to Government property.
952.245-2  Government property (fixed-price contracts).
952.245-5  Government property (cost-reimbursement, time-and-materials, 
          or labor-hour contracts).
952.247-70  Foreign travel.
952.249  Clauses related to termination.

[[Page 361]]

952.249-70  Termination clause for cost-reimbursement architect-engineer 
          contracts.
952.250  Clauses related to indemnification of contractors.
952.250-70  Nuclear hazards indemnity agreement.
952.250-71--952.250-72  [Reserved]
952.251-70  Contractor employee travel discounts.

    Authority:  42 U.S.C. 7254; 40 U.S.C. 486(c).

    Source:  49 FR 12042, Mar. 28, 1984, unless otherwise noted.



                         Subpart 952.0--General



952.000  Scope of part.

    This part implements FAR part 52 which sets forth contract clauses 
for use in connection with the acquisition of personal property and 
nonpersonal services (including construction), and supplements, as well 
as modifies, FAR part 52 by prescribing certain modifications to be made 
to FAR clauses when used in DOE contracts and specifying certain DOE 
contract clauses to be used in addition to or in place of such FAR 
clauses.



952.001  General policy.

    It is DOE policy to use the prescribed FAR and DOE contract clauses 
wherever practicable. Uniformity in the use of contract clauses helps to 
ensure impartial treatment of all contractors, expedites negotiation and 
contract review, and facilitates contract administration.



              Subpart 952.2--Text of Provisions and Clauses



952.202  Clauses related to definitions.



952.202-1  Definitions.

    (a) As prescribed in (FAR) 48 CFR 902.200, insert the clasue at 
(FAR) 48 CFR 52.202 in all contracts. The contracting officer shall 
substitute the following for paragraph (a) of the clause.

    (a) Head of Agency means the Secretary, Deputy Secretary or Under 
Secretary of the Department of Energy and the Chairman, Federal Energy 
Regulatory Commission.


    (b) The following shall be added as paragraph (h) except it will be 
designated paragraph (g) if Alternate I of the FAR clause is used.

    (h) The term DOE means the Department of Energy and FERC means the 
Federal Energy Regulatory Commission.
[49 FR 12042, Mar. 28, 1984, as amended at 50 FR 12185, Mar. 27, 1985; 
59 FR 9108, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.204  Clauses related to administrative matters.



952.204-2  Security requirements.

    As prescribed in 904.404(d)(1) the following clause shall be 
included in contracts entered into under section 31 (research 
assistance) or 41 (ownership and operation of production facilities) of 
the Atomic Energy Act of 1954, as amended, and in other contracts and 
subcontracts, which involve or are likely to involve classified 
information.

                           Security (SEP 1997)

    (a) Responsibility. It is the contractor's duty to safeguard all 
classified information, special nuclear material, and other DOE 
property. The contractor shall, in accordance with DOE security 
regulations and requirements, be responsible for safeguarding all 
classified information and protecting against sabotage, espionage, loss 
or theft of the classified documents and material in the contractor's 
posession in connection with the performance of work under this 
contract. Except as otherwise provided in this contract, the contractor 
shall, upon completion or termination of this contract, transmit to DOE 
any classified matter in the posession of the contractor or any person 
under the contractor's control in connection with performance of this 
contract. If retention by the contractor of any classified matter is 
required after the completion or termination of the contract, the 
contractor shall identify the items and types or categories of matter 
proposed for retention, the reasons for the retention of the matter, and 
the proposed period of retention. If the retention is approved by the 
contracting officer, the security provisions of the contract shall 
continue to be applicable to the matter retained. Special nuclear 
material shall not be retained after the completion or termination of 
the contract.
    (b) Regulations. The contractor agrees to comply with all security 
regulations and requirements of DOE in effect on the date of award.
    (c) Definition of classified information. The term classified 
information means Restricted Data, Formerly Restricted Data, or National 
Security Information.

[[Page 362]]

    (d) Definition of restricted data. The term Restricted Data means 
all data concerning (1) design, manufacture, or utilization of atomic 
weapons; (2) the production of special nuclear material; or (3) the use 
of special nuclear material in the production of energy, but shall not 
include data declassified or removed from the Restricted Data category 
pursuant to Section 142 of the Atomic Energy Act of 1954, as amended.
    (e) Definition of formerly restricted data. The term Formerly 
Restricted Data means all data removed from the Restricted Data category 
under section 142 d. of the Atomic Energy Act of 1954, as amended.
    (f) Definition of National Security Information. The term National 
Security Information means any information or material, regardless of 
its physical form or characteristics, that is owned by, produced for or 
by, or is under the control of the United States Government, that has 
been determined pursuant to Executive Order 12356 or prior Orders to 
require protection against unauthorized disclosure, and which is so 
designated.
    (g) Definition of Special Nuclear Material (SNM). SNM means: (1) 
plutonium, uranium enriched in the isotope 233 or in the isotope 235, 
and any other material which pursuant to the provisions of Section 51 of 
the Atomic Energy Act of 1954, as amended, has been determined to be 
special nuclear material, but does not include source material; or (2) 
any material artificially enriched by any of the foregoing, but does not 
include source material.
    (h) Security clearance of personnel. The contractor shall not permit 
any individual to have access to any classified information, except in 
accordance with the Atomic Energy Act of 1954, as amended, Executive 
Order 12356, and the DOE's regulations or requirements applicable to the 
particular level and category of classified information to which access 
is required.
    (i) Criminal liability. It is understood that disclosure of any 
classified information relating to the work or services ordered 
hereunder to any person not entitled to receive it, or failure to 
safeguard any classified information that may come to the contractor or 
any person under the contractor's control in connection with work under 
this contract, may subject the contractor, its agents, employees, or 
subcontractors to criminal liability under the laws of the United 
States. (See the Atomic Energy Act of 1954, as amended, 42 U.S.C. 2011 
et seq.; 18 U.S.C. 793 and 794; and E.O. 12356.)
    (j) Subcontracts and purchase orders. Except as otherwise authorized 
in writing by the contracting officer, the contractor shall insert 
provisions similar to the foregoing in all subcontracts and purchase 
orders under this contract.
[49 FR 12042, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 52 
FR 38425, Oct. 16, 1987; 59 FR 9108, Feb. 25, 1994; 62 FR 42074, Aug 5, 
1997]



952.204-70  Classification.

    As prescribed in 904.404(d)(2), the following clause shall be 
included in all contracts which involve classified information.

                        Classification (Apr 1984)

    In the performance of the work under this contract, the contractor 
shall ensure that an Authorized Original Classifier or Derivative 
Classifier shall assign classifications to all documents, material, and 
equipment originated or generated under the contract in accordance with 
classification regulations and guidance furnished to the contractor by 
the DOE. Every subcontract and purchase order issued hereunder involving 
the origination or generation of classified documents, material, or 
equipment shall include a provision to the effect that in the 
performance of such subcontract or purchase order, the subcontractor or 
supplier shall ensure that an Authorized Original Classifier or 
Derivative Classifier shall assign classifications to all such 
documents, materials, and equipment in accordance with classification 
regulations and guidance furnished to such subcontractor or supplier by 
the contractor.
[49 FR 12042, Mar. 28, 1984, as amended at 59 FR 9108, Feb. 25, 1994]



952.204-71  Sensitive foreign nations controls.

    In accordance with 904.404(d)(3), the contracting officer shall 
include the following clause.

              Sensitive Foreign Nations Controls (Apr 1994)

    (a) In connection with any activities in the performance of this 
contract, the contractor agrees to comply with the ``Sensitive Foreign 
Nations Controls'' requirements attached to this contract, relating to 
those countries, which may from time to time, be identified to the 
contractor by written notice as sensitive foreign nations. The 
contractor shall have the right to terminate its performance under this 
contract upon at least 60 days' prior written notice to the contracting 
officer if the contractor determines that it is unable, without 
substantially

[[Page 363]]

interfering with its polices or without adversely impacting its 
performance to continue performance of the work under this contract as a 
result of such notification. If the contractor elects to terminate 
performance, the provisions of this contract regarding termination for 
the convenience of the Government shall apply.
    (b) The provisions of this clause shall be included in any 
subcontracts.
[49 FR 12042, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 59 
FR 9108, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.204-72  Disclosure of information.

    As prescribed in 904.404(d)(4) this clause may be used in place of 
the clauses entitled ``Security,'' 952.204-2, and ``Classification,'' 
952.204-70, in contracts with educational institutions for research 
involving nuclear technology which could but is not expected to produce 
classified information or restricted data.

                  Disclosure of Information (Apr 1994)

    (a) It is mutually expected that the activities under this contract 
will not involve classified information. It is understood, however, that 
if in the opinion of either party, this expectation changes prior to the 
expiration or terminating of all activities under this contract, said 
party shall notify the other party accordingly in writing without delay. 
In any event, the contractor shall classify, safeguard, and otherwise 
act with respect to all classified information in accordance with 
applicable law and the requirements of DOE, and shall promptly inform 
DOE in writing if and when classified information becomes involved, or 
in the mutual judgment of the parties it appears likely that classified 
information or material may become involved. The contractor shall have 
the right to terminate performance of the work under this contract and 
in such event the provisions of this contract respecting termination for 
the convenience of the Government shall apply.
    (b) The contractor shall not permit any individual to have access to 
classified information except in accordance with the Atomic Energy Act 
1954, as amended, Executive Order 12356, and DOE's regulations or 
requirements.
    (c) The term Restricted Data as used in this article means all data 
concerning the design, manufacture, or utilization of atomic weapons, 
the production of special nuclear material or the use of special nuclear 
material in the production of energy, but shall not include data 
declassified or removed from the Restricted Data category pursuant to 
section 142 of the Atomic Energy Act of 1954, as amended.
[49 FR 12042, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 59 
FR 9108, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.204-73  Foreign ownership, control, or influence over contractor (Representation).

    As prescribed in 904.7005(a), insert the following provision in all 
solicitations for contracts subject to the provisions of 904.70.

   Foreign Ownership, Control, or Influence Over Contractor (JUL 1997)

    (a) For purposes of this provision, a foreign interest is defined as 
any of the following:
    (1) A foreign government or foreign government agency;
    (2) Any form of business enterprise organized under the laws of any 
country other than the United States or its possessions;
    (3) Any form of business enterprise organized or incorporated under 
the laws of the U.S., or a State or other jurisdiction within the U.S., 
which is owned, controlled, or influenced by a foreign government, 
agency, firm, corporation, or person; or
    (4) Any person who is not a U.S. citizen.
    (b) Foreign ownership, control, or influence (FOCI) means the 
situation where the degree of ownership, control, or influence over a 
contractor by a foreign interest is such that a reasonable basis exists 
for concluding that compromise of classified information or significant 
quantity of special nuclear material as defined in 10 CFR part 710 may 
result.
    (c) If the offeror has not previously submitted responses to the 
following questions to DOE as part of the facility security clearance 
process, then it shall answer the following questions. Answer each 
question in either the ``yes'' or ``no'' column. If the answer is yes, 
furnish in detail on a separate sheet of paper all the information 
requested in parentheses. Copies of information which responds to these 
questions and which was submitted to other Government agencies may be 
submitted as responses to these questions if the earlier responses are 
accurate, complete, and current.

                                                                        
------------------------------------------------------------------------
                         Question                            Yes     No 
------------------------------------------------------------------------
1. Does a foreign interest own or have beneficial                       
 ownership in 5% of more of your organization's voting                  
 securities?..............................................  .....  .....

[[Page 364]]

                                                                        
  (Identify the percentage of any class of shares or other              
   securities issued which are owned by foreign interests,              
   listed by country. If you answer ``Yes'' and have                    
   received from an investor a copy of Schedule 13D and/or              
   Schedule 13G filed by the investors with the Securities              
   and Exchange Commission, you are to attach a copy of                 
   Schedule 13D and/or Schedule 13G.)                                   
2. Does your organization own 10% or more of any foreign                
 interest?................................................  .....  .....
  (Furnish the name of the foreign interest, address by                 
   country, and the percentage owned. Include name and                  
   title of officials of your organization who occupy                   
   positions with the foreign interest, if any.)                        
3. Do any foreign interests have management positions such              
 as directors, officers, or executive personnel in your                 
 organization?............................................  .....  .....
  (Furnish full information concerning the identity of the              
   foreign interest and the position he/she holds in your               
   organization.)                                                       
4. Does any foreign interest control or influence, or is                
 any foreign interest in a position to control or                       
 influence the election, appointment, or tenure of any of               
 your directors, officers, or executive personnel?........  .....  .....
  (Identify the foreign interest(s) and furnish full                    
   details concerning the control or influence.)                        
5. Does your organization have any contracts, binding                   
 agreements, understandings, or arrangements with a                     
 foreign interest(s) that cumulatively represent 10% or                 
 more of your organization's gross income?................  .....  .....
  (Furnish the name of the foreign interest, country,                   
   nature of agreement or involvement. Agreements include               
   licensing, sales, patent exchange, trade secrets,                    
   agency, cartel, partnership, joint venture, proxy, etc.              
   Give overall percentage by country as related to total               
   income and type of services or products in general                   
   terms. If you answer ``Yes'' and have received from the              
   foreign interest a copy of Schedule 13D and/or Schedule              
   13G filed by the foreign interest with the Securities                
   and Exchange Commission, you are to attach a copy of                 
   Schedule 13D and/or Schedule 13G.)                                   
6. Is your organization indebted to foreign interests?....  .....  .....
  (Furnish the amount of indebtedness as related to the                 
   current assets of the organization and identify the                  
   creditor. Include specifics as to the type of                        
   indebtedness and what, if any, collateral, including                 
   voting stock, has been furnished or pledged. If any                  
   debentures are convertible, specifics about the                      
   indebtedness, collateral, if any, and what will be                   
   received after conversion are to be furnished.)                      
7. Does your organization derive any income from Communist              
 countries included in Country Groups Q, S, W, Y, and Z in              
 Supplement No. 1 in 15 CFR part 770?.....................  .....  .....
  (Discuss in detail any income derived from Communist                  
   countries, including percentage from each such country               
   as related to total income, and the type of services or              
   products involved.)                                                  
8. Is 5% or more of any class of your organization's                    
 securities held in ``nominee shares,'' in ``street                     
 names'', or in some other method which does not disclose               
 beneficial owner of equitable title?.....................  .....  .....
  (Identify each foreign institutional investor holding 5               
   percent or more of the voting stock. Identification                  
   should include the name and address of the investor and              
   percentage of stock held. State whether the investor                 
   has attempted to, or has, exerted any management                     
   control or influence over the appointment of directors,              
   officers, or other key management personnel, and                     
   whether such investors have attempted to influence the               
   policies of the corporation. If you have received from               
   the investor a copy of the Schedule 13D and/or Schedule              
   13G filed by the investor with the Securities and                    
   Exchange Commission, you are to attach a copy of                     
   Schedule 13D and/or Schedule 13G.)                                   
9. Does your organization have interlocking directors with              
 foreign interests?.......................................  .....  .....
  (Include identifying data on all such directors. If they              
   have a security clearance, so state. Also indicate the               
   name and address of all other corporations with which                
   they serve in any capacity.)                                         
10. Are there any citizens of foreign countries employed                
 by, or who may visit, your offices or facilities in a                  
 capacity which may permit them to have access to                       
 classified information or a significant quantity of                    
 special nuclear material?................................  .....  .....
  (Provide complete information by identify the                         
   individuals and the country of which they are                        
   citizens.)                                                           
11. Does your organization have foreign involvement not                 
 otherwise covered in your answers to the above questions?  .....  .....
  (Describe the foreign involvement in detail, including                
   why the involvement would not be reportable in the                   
   preceding questions.)                                                
------------------------------------------------------------------------

    (d) Prior to award of a contract under this solicitation, the DOE 
must determine that award of the contract to the offeror will not pose 
an undue risk to the common defense and security as a result of its 
access to classified information or a significant quantity of special 
nuclear material in the performance of the contract. In making the 
determination, the contracting officer may consider a voting trust or 
other arrangements proposed by the offeror to mitigate or avoid FOCI. 
The contracting officer may require the offeror to submit such 
additional information as deemed pertinent to this determination.
    (e) The offeror shall require any subcontractors having access to 
classified information or a significant quantity of special nuclear 
material to provide responses to the

[[Page 365]]

questions in paragraph (c) of this provision directly to the DOE 
contracting officer.
    (f) Information submitted by the offeror in response to the 
questions in (c) above is to be used solely for purposes of evaluating 
foreign ownership, control, or influence and shall be treated by DOE, to 
the extent permitted by law, as business or financial information 
submitted in confidence.

                      Alternate I December 10, 1993

    If the solicitation is part of the national security program and 
will require access to proscribed information to enable performance, add 
the following notice.

                                 Notice

    Statute prohibits the award of a contract under a national security 
program to a company owned by an entity controlled by a foreign 
government unless a waiver is granted by the Secretary of Energy.
[49 FR 12042, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 56 
FR 41965, Aug. 26, 1991; 58 FR 59684, Nov. 10, 1993; 59 FR 9108, Feb. 
25, 1994; 62 FR 42074, Aug. 5, 1997]



952.204-74  Foreign ownership, control, or influence over contractor.

    As prescribed in 904.7005(b), insert the following contract clause 
in new contracts and contract modifications to existing contracts 
subject to 904.70.

   Foreign Ownership, Control, or Influence Over Contractor (Apr 1984)

    (a) For purposes of this clause, a foreign interest is defined as 
any of the following:
    (1) A foreign government or foreign government agency;
    (2) Any form of business enterprise organized under the laws of any 
country other than the United States or its possessions;
    (3) Any form of business enterprise organized or incorporated under 
the laws of the U.S., or a State or other jurisdiction within the U.S., 
which is owned, controlled, or influenced by a foreign government, 
agency, firm, corporation or person; or
    (4) Any person who is not a U.S. citizen.
    (b) Foreign ownership, control, or influence (FOCI) means the 
situation where the degree of ownership, control, or influence over a 
contractor by a foreign interest is such that a reasonable basis exists 
for concluding that compromise of classified information, special 
nuclear material as defined in 10 CFR part 710, may result.
    (c) For purposes of this clause, subcontractor means any 
subcontractor at any tier and the term contracting officer shall mean 
DOE contracting officer. When this clause is included in a subcontract, 
the term contractor shall mean subcontractor and the term contract shall 
mean subcontract.
    (d) The contractor shall immediately provide the contracting officer 
written notice of any changes in the extent and nature of FOCI over the 
contractor which would affect the answers to the questions presented in 
DEAR 952.204-73. Further, notice of changes in ownership or control 
which are required to be reported to the Securities and Exchange 
Commission, the Federal Trade Commission, or the Department of Justice 
shall also be furnished concurrently to the contracting officer.
    (e) In those cases where a contractor has changes involving FOCI, 
the DOE must determine whether the changes will pose an undue risk to 
the common defense and security. In making this determination, the 
contracting officer shall consider proposals made by the contractor to 
avoid or mitigate foreign influences.
    (f) If the contracting officer at any time determines that the 
contractor is, or is potentially, subject to FOCI, the contractor shall 
comply with such instructions as the contracting officer shall provide 
in writing to safeguard any classified information or significant 
quantity of special nuclear material.
    (g) The contractor agrees to insert terms that conform substantially 
to the language of this clause including this paragraph (g) in all 
subcontracts under this contract that will require access to classified 
information or a significant quantity of special nuclear material. 
Additionally, the contractor shall require such subcontractors to submit 
a completed certification required in DEAR 952.204-73 prior to award of 
a subcontract. Information to be provided by a subcontractor pursuant to 
this clause may be submitted directly to the contracting officer.
    (h) Information submitted by the contractor or any affected 
subcontractor as required pursuant to this clause shall be treated by 
DOE to the extent permitted by law, as business or financial information 
submitted in confidence to be used solely for purposes of evaluating 
FOCI.
    (i) The requirements of this clause are in addition to the 
requirement that a contractor obtain and retain the security clearances 
required by the contract. This clause shall not operate as a limitation 
on DOE's rights, including its rights to terminate this contract.
    (j) The contracting officer may terminate this contract for default 
either if the contractor fails to meet obligations imposed by this 
clause, e.g., provide the information required by this clause, comply 
with the contracting officer's instructions about safeguarding 
classified information, or make this clause applicable to 
subcontractors, or if, in the contracting officer's judgment, the 
contractor creates an FOCI situation in

[[Page 366]]

order to avoid performance or a termination for default. The contracting 
officer may terminate this contract for convenience if the contractor 
becomes subject to FOCI and for reasons other than avoidance of 
performance of the contract, cannot, or chooses not to, avoid or 
mitigate the FOCI problem.



952.208  Clauses related to required sources of supply.



952.208-7  Tagging of leased vehicles.

    As prescribed in 908.7101-7, insert the following clause when 
leasing commercial vehicles for periods in excess of 60 days.

                  Tagging of Leased Vehicles (Apr 1984)

    (a) DOE intends to use U.S. Government license tags.
    (b) While it is the intention that vehicles leased hereunder shall 
operate on Federal tags, the DOE reserves the right to utilize State 
tags if necessary to accomplish its mission. Should State tags be 
required, the contractor shall furnish the DOE the documentation 
required by the State to acquire such tags.
[49 FR 12042, Mar. 28, 1984, as amended at 59 FR 9108, Feb. 25, 1994]



952.208-70  Printing.

    As prescribed in 908.802, insert the following clause.

                           Printing (Apr 1984)

    The contractor shall not engage in, nor subcontract for, any 
printing (as that term is defined in Title I of the U.S. Government 
Printing and Binding Regulations in effect on the effective date of this 
contract) in connection with the performance of work under this 
contract. Provided, however, that performance of a requirement under 
this contract involving the duplication of less than 5,000 copies of a 
single unit, or no more than 25,000 units in the aggregate of multiple 
units, will not be deemed to be printing. A unit is defined as one 
sheet, size 8\1/2\ by 11 inches one side only, one color. A requirement 
is defined as a single publication document.
    (1) The term printing includes the following processes: composition, 
plate making, presswork, binding, microform publishing, or the end items 
produced by such processes.
    (2) If fulfillment of the contract will necessitate reproduction in 
excess of the limits set forth above, the contractor shall notify the 
contracting officer in writing and obtain the contracting officer's 
approval prior to acquiring on DOE's behalf production, acquisition, and 
dissemination of printed matter. Such printing must be obtained from the 
Government Printing Office (GPO), a contract source designated by GPO or 
a Joint Committee on Printing authorized federal printing plant.
    (3) Printing services not obtained in compliance with this guidance 
will result in the cost of such printing being disallowed.
    (4) The Contractor will include in each of his subcontracts 
hereunder a provision substantially the same as this clause including 
this paragraph (4).
[49 FR 12042, Mar. 28, 1984; 49 FR 38951, Oct. 2, 1984, as amended at 59 
FR 9108, Feb. 25, 1994]



952.209  Clauses related to contractor's qualifications.



952.209-8  Organizational Conflicts of Interest-Disclosure.

    As prescribed in 48 CFR 909.507-1(e), insert the following 
provision:

Organizational Conflicts of Interest Disclosure-Advisory and Assistance 
                          Services (June 1997)

    (a) Organizational conflict of interest means that because of other 
activities or relationships with other persons, a person is unable or 
potentially unable to render impartial assistance or advice to the 
Government, or the person's objectivity in performing the contract work 
is or might be otherwise impaired, or a person has an unfair competitive 
advantage.
    (b) An offeror notified that it is the apparent successful offeror 
shall provide the statement described in paragraph (c) of this 
provision. For purposes of this provision, ``apparent successful 
offeror'' means the proposer selected for final negotiations or, where 
individual contracts are negotiated with all firms in the competitive 
range, it means all such firms.
    (c) The statement must contain the following:
    (1) A statement of any past (within the past twelve months), 
present, or currently planned financial, contractual, organizational, or 
other interests relating to the performance of the statement of work. 
For contractual interests, such statement must include the name, 
address, telephone number of the client or client(s), a description of 
the services rendered to the previous client(s), and the name of a 
responsible officer or employee of the offeror who is knowledgeable 
about the services rendered to each client, if, in the 12 months 
preceding the date of the statement, services were rendered to the 
Government or any other client (including a foreign government or 
person) respecting the

[[Page 367]]

same subject matter of the instant solicitation, or directly relating to 
such subject matter. The agency and contract number under which the 
services were rendered must also be included, if applicable. For 
financial interests, the statement must include the nature and extent of 
the interest and any entity or entities involved in the financial 
relationship. For these and any other interests enough such information 
must be provided to allow a meaningful evaluation of the potential 
effect of the interest on the performance of the statement of work.
    (2) A statement that no actual or potential conflict of interest or 
unfair competitive advantage exists with respect to the advisory and 
assistance services to be provided in connection with the instant 
contract or that any actual or potential conflict of interest or unfair 
competitive advantage that does or may exist with respect to the 
contract in question has been communicated as part of the statement 
required by (b) of this provision.
    (d) Failure of the offeror to provide the required statement may 
result in the offeror being determined ineligible for award. 
Misrepresentation or failure to report any fact may result in the 
assessment of penalties associated with false statements or such other 
provisions provided for by law or regulation.

    (End of provision)
[62 FR 40752, July 30, 1997]



952.209-71  [Reserved]



952.209-72   Organizational conflicts of interest.

    As prescribed at 48 CFR 909.507-2, insert the following clause:

            Organizational Conflicts of Interest (June 1997)

    (a) Purpose. The purpose of this clause is to ensure that the 
contractor (1) is not biased because of its financial, contractual, 
organizational, or other interests which relate to the work under this 
contract, and (2) does not obtain any unfair competitive advantage over 
other parties by virtue of its performance of this contract.
    (b) Scope. The restrictions described herein shall apply to 
performance or participation by the contractor and any of its affiliates 
or their successors in interest (hereinafter collectively referred to as 
``contractor'') in the activities covered by this clause as a prime 
contractor, subcontractor, cosponsor, joint venturer, consultant, or in 
any similar capacity. For the purpose of this clause, affiliation occurs 
when a business concern is controlled by or has the power to control 
another or when a third party has the power to control both.
    (1) Use of Contractor's Work Product. (i) The contractor shall be 
ineligible to participate in any capacity in Department contracts, 
subcontracts, or proposals therefor (solicited and unsolicited) which 
stem directly from the contractor's performance of work under this 
contract for a period of (Contracting Officer see DEAR 9.507-2 and enter 
specific term) years after the completion of this contract. Furthermore, 
unless so directed in writing by the contracting officer, the Contractor 
shall not perform any advisory and assistance services work under this 
contract on any of its products or services or the products or services 
of another firm if the contractor is or has been substantially involved 
in their development or marketing. Nothing in this subparagraph shall 
preclude the contractor from competing for follow-on contracts for 
advisory and assistance services.
    (ii) If, under this contract, the contractor prepares a complete or 
essentially complete statement of work or specifications to be used in 
competitive acquisitions, the contractor shall be ineligible to perform 
or participate in any capacity in any contractual effort which is based 
on such statement of work or specifications. The contractor shall not 
incorporate its products or services in such statement of work or 
specifications unless so directed in writing by the contracting officer, 
in which case the restriction in this subparagraph shall not apply.
    (iii) Nothing in this paragraph shall preclude the contractor from 
offering or selling its standard and commercial items to the Government.
    (2) Access to and use of information. (i) If the contractor, in the 
performance of this contract, obtains access to information, such as 
Department plans, policies, reports, studies, financial plans, internal 
data protected by the Privacy Act of 1974 (5 U.S.C. 552a), or data which 
has not been released or otherwise made available to the public, the 
contractor agrees that without prior written approval of the contracting 
officer it shall not:
    (A) use such information for any private purpose unless the 
information has been released or otherwise made available to the public;
    (B) compete for work for the Department based on such information 
for a period of six (6) months after either the completion of this 
contract or until such information is released or otherwise made 
available to the public, whichever is first;
    (C) submit an unsolicited proposal to the Government which is based 
on such information until one year after such information is released or 
otherwise made available to the public; and
    (D) release such information unless such information has previously 
been released or otherwise made available to the public by the 
Department.

[[Page 368]]

    (ii) In addition, the contractor agrees that to the extent it 
receives or is given access to proprietary data, data protected by the 
Privacy Act of 1974 (5 U.S.C. 552a), or other confidential or privileged 
technical, business, or financial information under this contract, it 
shall treat such information in accordance with any restrictions imposed 
on such information.
    (iii) The contractor may use technical data it first produces under 
this contract for its private purposes consistent with paragraphs 
(b)(2)(i) (A) and (D) of this clause and the patent, rights in data, and 
security provisions of this contract.
    (c) Disclosure after award. (1) The contractor agrees that, if 
changes, including additions, to the facts disclosed by it prior to 
award of this contract, occur during the performance of this contract, 
it shall make an immediate and full disclosure of such changes in 
writing to the contracting officer. Such disclosure may include a 
description of any action which the contractor has taken or proposes to 
take to avoid, neutralize, or mitigate any resulting conflict of 
interest. The Department may, however, terminate the contract for 
convenience if it deems such termination to be in the best interest of 
the Government.
    (2) In the event that the contractor was aware of facts required to 
be disclosed or the existence of an actual or potential organizational 
conflict of interest and did not disclose such facts or such conflict of 
interest to the contracting officer, DOE may terminate this contract for 
default.
    (d) Remedies. For breach of any of the above restrictions or for 
nondisclosure or misrepresentation of any facts required to be disclosed 
concerning this contract, including the existence of an actual or 
potential organizational conflict of interest at the time of or after 
award, the Government may terminate the contract for default, disqualify 
the contractor from subsequent related contractual efforts, and pursue 
such other remedies as may be permitted by law or this contract.
    (e) Waiver. Requests for waiver under this clause shall be directed 
in writing to the contracting officer and shall include a full 
description of the requested waiver and the reasons in support thereof. 
If it is determined to be in the best interests of the Government, the 
contracting officer may grant such a waiver in writing.

    (End of clause)

    ALTERNATE I: In accordance with 909.507-2 and 970.0905, include the 
following alternate in the specified types of contracts.
    (f) Subcontracts. (1) The contractor shall include a clause, 
substantially similar to this clause, including this paragraph (f), in 
subcontracts expected to exceed the simplified acquisition threshold 
determined in accordance with FAR part 13 and involving the performance 
of advisory and assistance services as that term is defined at FAR 
37.201. The terms ``contract,'' ``contractor,'' and ``contracting 
officer'' shall be appropriately modified to preserve the Government's 
rights.
    (2) Prior to the award under this contract of any such subcontracts 
for advisory and assistance services, the contractor shall obtain from 
the proposed subcontractor or consultant the disclosure required by DEAR 
909.507-1, and shall determine in writing whether the interests 
disclosed present an actual or significant potential for an 
organizational conflict of interest. Where an actual or significant 
potential organizational conflict of interest is identified, the 
contractor shall take actions to avoid, neutralize, or mitigate the 
organizational conflict to the satisfaction of the contractor. If the 
conflict cannot be avoided or neutralized, the contractor must obtain 
the approval of the DOE contracting officer prior to entering into the 
subcontract.

    (End of alternate)
[62 FR 40752, July 30, 1997]



952.211  Clauses related to contract delivery or performance.



952.211-70  Priorities and allocations for energy programs (solicitations).

    As prescribed in 911.604(a), insert the following provision in 
solicitations that will result in the award of a contract in support of 
DOE atomic energy programs.

          Priorities and Allocations (Atomic Energy) (JUN 1996)

    Contracts or purchase orders awarded as a result of this 
solicitation shall be assigned a   DO-Rating; 
  DX-Rating; and certified for national defense use in 
accordance with the Defense Priorities and Allocations System (DPAS) 
regulation (15 CFR part 700) (Contracting officer check appropriate 
box.).

                               Alternate I

    As prescribed in 911.604(d), insert the following provision in 
solicitations in support of a program or project which may be determined 
to maximize domestic energy supplies:

    Priorities and Allocations (Domestic Energy Supplies) (JUN 1996)

    Contracts or purchase orders awarded as a result of this 
solicitation may be eligible for priorities and allocations support in 
accordance with 10 CFR part 216 and section 101(c)

[[Page 369]]

of the Defense Production Act of 1950, as amended.
[52 FR 38425, Oct. 16, 1987, as amended at 59 FR 9109, Feb. 25, 1994. 
Redesignated and amended at 61 FR 21977, May 13, 1996; 61 FR 30823, June 
18, 1996]



952.211-71  Priorities and allocations for energy programs (contracts).

    As prescribed in 911.604(b), insert the following clause in 
contracts and purchase orders that are placed in support of authorized 
DOE atomic energy programs pursuant to the Atomic Energy Act of 1954, as 
amended.

          Priorities and Allocations (Atomic Energy) (JUN 1996)

    The Contractor shall follow the provisions of Defense Priorities and 
Allocations System (DPAS) regulation (15 CFR part 700) in obtaining 
controlled materials and other products and materials needed to fill 
this contract.

                               Alternate I

    As prescribed in 911.604(e), insert the following clause in 
contracts if they are placed in support of programs or projects which 
may be determined to maximize domestic energy supplies:

    Priorities and Allocations (Domestic Energy Supplies) (JUN 1996)

    (a) This contract may be eligible for priorities and allocations 
support, as provided for by section 101(c) of the Defense Production Act 
of 1950, as amended by the Energy Policy and Conservation Act (Pub. L. 
94-163, 42 U.S.C. 6201 et seq.) if its purpose is determined to be to 
maximize domestic energy supplies. Eligibility is dependent on an 
executive decision on a case-by-case basis with the decision being 
jointly made by the Departments of Energy and Commerce.
    (b) DOE regulations regarding material allocations and priority 
performance under contracts or orders to maximize domestic energy 
supplies can be found at part 216 of title 10 of the Code of Federal 
Regulations (10 CFR part 216).
    (c) Additional guidance is provided by DOE Publication MA-0192, 
``Priorities and Allocations Support for Energy: Keeping Energy Programs 
on Schedule,'' dated August 1985, as it may from time to time be 
revised. Copies may be obtained by written request to: Department of 
Energy, Office of Scientific and Technical Information (OSTI), Post 
Office Box 62, Oak Ridge, Tennessee 37830.
[52 FR 38426, Oct. 16, 1987, as amended at 59 FR 9109, Feb. 25, 1994. 
Redesignated and amended at 61 FR 21977, May 13, 1996; 61 FR 30823, June 
18, 1996]



952.211-72  [Reserved]



952.211-73  [Reserved]



952.216  Clauses related to types of contracts.



952.216-7  Allowable cost and payment.

    Alternate I: If the contract is with a nonprofit organization, other 
than an educational institution; or a State or local government, modify 
the clause at FAR 52.216-7 Allowable Cost and Payment by deleting from 
paragraph (a) the phrase ``Subpart 31.2'' and substituting for it 
``Subpart 31.7.''
    Alternate II: When contracting with a commercial organization modify 
paragraph (a) of the clause at FAR 52.216-7 by adding the phrase ``as 
supplemented by Subpart 931.2 of the Department of Energy Acquisition 
Regulations (DEAR),'' after the acronym ``(FAR)''.



952.216-15  Predetermined indirect cost rates.

    Alternate (APR 1994): As prescribed in 916.307(j), modify paragraph 
(c) of the clause at FAR 52.216-15, Predetermined Indirect Cost Rates, 
by deleting the words ``Subpart 31.3'' and substituting for them 
``Subpart 31.6'' and insert the clause in solicitations and contracts 
when a cost-reimbursement research and development contract with a State 
or local government is contemplated and predetermined indirect cost 
rates are to be used.
[49 FR 12042, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994; 62 
FR 2312, Jan. 16, 1997]



952.217-70  Acquisition of real property.

    Insert the following clause when required by 917.7403(c).

                 Acquisition of Real Property (Apr 1984)

    (a) Notwithstanding any other provision of the contract, the prior 
approval of the contracting officer shall be obtained when, in 
performance of this contract, the contractor acquires or proposes to 
acquire use of real property by:
    (1) Purchase, on the Government's behalf or in the contractor's own 
name, with title eventually vesting in the Government.

[[Page 370]]

    (2) Lease, and the Government assumes liability for, or will 
otherwise pay for the obligation under the lease as a reimbursable 
contract cost.
    (3) Acquisition of temporary interest through easement, license or 
permit, and the Government funds the entire cost of the temporary 
interest.
    (b) Justification of and execution of any real property acquisitions 
shall be in accordance and compliance with directions provided by the 
contracting officer.
    (c) The substance of this clause, including this paragraph (c), 
shall be included in any subcontract occasioned by this contract under 
which property described in paragraph (a) of this clause shall be 
acquired.



952.222-70  Whistleblower protection for contractor employees.

    As prescribed in 922.7101, insert the clause at 970.5204-59, in 
contracts other than management and operating contracts and in purchase 
orders, that involve work to be performed on-site at a DOE-owned or -
leased facility, after adding to the end of paragraph (a) of that 
clause, the phrase ``with respect to work performed on-site at a DOE-
owned or -leased facility, as provided for at part 708.''
[57 FR 57639, Dec. 4, 1993; 58 FR 39679, July 26, 1993]



952.223  Clauses related to environment, conservation, and occupational safety.



952.223-71  Integration of environment, safety, and health into work planning and execution.

    As prescribed in 923.7002 the clause set forth at 970.5204-2 shall 
be included in all contracts and subcontracts for, and be made 
applicable to, work to be performed at a government-owned or leased 
facility where DOE has elected to assert its statutory authority to 
establish and enforce occupational safety and health standards 
applicable to the work conditions of contractor and subcontractor 
employees, and to the protection of the public health and safety.
[49 FR 12042, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994]



952.223-72  Radiation protection and nuclear criticality.

    As prescribed in 923.7002 the clause set forth herein shall be 
included in those contracts or subcontracts for, and be made applicable 
to, work to be performed at a facility where DOE does not elect to 
assert its statutory authority to enforce occupational safety and health 
standards applicable to the working conditions of contractor and 
subcontractor employees, but does need to enforce radiological safety 
and health standards pursuant to provisions of the contract or 
subcontract rather than by reliance upon Nuclear Regulatory Commission 
licensing requirements (including agreements with states under section 
274 of the Atomic Energy Act).

         Radiation Protection and Nuclear Criticality (Apr 1984)

    The contractor shall take all reasonable precautions in the 
performance of work under this contract to protect the safety and health 
of employees and of members of the public against the hazards of 
ionizing radiation and radioactive materials and shall comply with all 
applicable radiation protection and nuclear criticality safety standards 
and requirements (including reporting requirements) of DOE. The 
contractor shall submit a management program and implementation plan to 
the contracting officer for review and approval within 30 days after the 
effective date of this contract or modification. In the event that the 
contractor fails to comply with said standards and requirements of DOE, 
the contracting officer may, without prejudice to any other legal or 
contractual rights of DOE, issue an order stopping all or any part of 
the work. Thereafter, a start order for resumption of the work may be 
issued at the discretion of the contracting officer. The contractor 
shall make no claim for an extension of time or for compensation or 
damages by reason of or in connection with such work stoppage.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994]



952.223-73  [Reserved]



952.223-74  [Reserved]



952.223-75  Preservation of individual occupational radiation exposure records.

    The contracting officer shall insert this clause in contracts 
containing 952.223-71, Integration of environment, safety, and health 
into work planning and execution, or 952.223-72, Radiation protection 
and nuclear criticality.

[[Page 371]]

Preservation of Individual Occupational Radiation Exposure Records (Apr 
                                  1984)

    Individual occupational radiation exposure records generated in the 
performance of work under this contract shall be subject to inspection 
by DOE and shall be preserved by the contractor until disposal is 
authorized by DOE or at the option of the contractor delivered to DOE 
upon completion or termination of the contract. If the contractor 
exercises the foregoing option, title to such records shall vest in DOE 
upon delivery.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994; 62 FR 34862, June 27, 1997]



952.224-70  Paperwork Reduction Act.

    Insert the following clause if it is anticipated that information 
collection from 10 or more persons will be necessary under the contract.

                   Paperwork Reduction Act (Apr 1994)

    (a) In the event that it subsequently becomes a contractual 
requirement to collect or record information calling either for answer 
to identical questions from 10 or more persons other than Federal 
employees, or information from Federal employees which is to be used for 
statistical compilations of general public interest, the Paperwork 
Reduction Act will apply to this contract. No plan, questionnaire, 
interview guide, or other similar device for collecting information 
(whether repetitive or single-time) may be used without first obtaining 
clearance from the Office of Management and Budget (OMB).
    (b) The contractor shall request the required OMB clearance from the 
contracting officer before expending any funds or making public contacts 
for the collection of data. The authority to expend funds and to proceed 
with the collection of data shall be in writing by the contracting 
officer. The contractor must plan at least 90 days for OMB clearance. 
Excessive delay caused by the Government which arises out of causes 
beyond the control and without the fault or negligence of the contractor 
will be considered in accordance with the clause entitled ``Excusable 
Delays,'' if such clause is applicable. If not, the period of 
performance may be extended pursuant to this clause if approved by the 
contracting officer.
[49 FR 12042, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994; 62 
FR 2312, Jan. 16, 1997]



952.225-70  Subcontracting for nuclear hot cell services.

    As prescribed in 925.7004, insert the following clause in 
solicitations and contracts.

         Subcontracting for Nuclear Hot Cell Services (Mar 1993)

    (a) Definitions.
    Costs related to the decommissioning of nuclear facilities, as used 
in this clause, means any cost associated with the compliance with 
regulatory requirements governing the decommissioning of nuclear 
facilities licensed by the Nuclear Regulatory Commission. Such costs for 
foreign facilities and for Department of Energy facilities are costs of 
decommissioning associated with the compliance with foreign regulatory 
requirements or the Department's own requirements.
    Costs related to the storage and disposal of nuclear waste, as used 
in this clause, means any costs, whether required by regulation or 
incurred as a matter of prudent business practice, associated with the 
storage or disposal of nuclear waste.
    Foreign company, as used in this clause, means a company which 
offers to perform nuclear hot cell services at a facility which is not 
subject to the laws and regulations of the United States, its agencies, 
and its political subdivisions.
    Nuclear hot cell services, as used in this clause, means services 
related to the examination of, or performance of various operations on, 
nuclear fuel rods, control assemblies, or other components that are 
emitting large quantities of ionizing radiation, after discharge from 
nuclear reactors, which are performed in specialized facilities located 
away from commercial nuclear power plants, generally referred to in the 
industry as ``hot cells.''
    Nuclear waste, as used in this clause, means any radioactive waste 
material subject to regulation by the Nuclear Regulatory Commission or 
the Department of Energy, or in the case of foreign offers, by 
comparable foreign organizations.
    United States company, as used in this clause, means a company which 
offers to perform nuclear hot cell services at a facility subject to the 
laws and regulations of the United States, its agencies, and its 
political subdivisions.
    (b) In selecting a competitive offer for a first-tier subcontract 
acquisition of nuclear hot cell services, the contractor shall (1) 
consider neither costs related to the decommissioning of nuclear waste 
facilities nor costs related to the storage and disposal of nuclear 
waste, or (2) add these costs to offers of foreign companies, if--

[[Page 372]]

    (i) one or more of the offers is submitted by a United States 
company and includes costs related to the decommissioning of nuclear 
facilities and costs related to the storage and disposal of nuclear 
waste because it is subject to such cost; and
    (ii) one or more of the offers is submitted by a foreign company and 
does not include these types of costs. (A foreign company might not be 
subject to such costs or might not have to include these types of cost 
in its offer if the firm is subsidized in decommissioning activity or 
storage and disposal of nuclear waste, or a foreign government is 
performing the activities below the actual cost of the activity.)
    (c) Upon determining that no offer from a foreign firm has a 
reasonable chance of being selected for award, the requirements of this 
clause will not apply.
[58 FR 8911, Feb. 18, 1993; 58 FR 39679, July 26, 1993]



952.226-70  Subcontracting goals under section 3021(a) of the Energy Policy Act of 1992.

    As prescribed in 926.7007(a), insert the following provision:

 Subcontracting Goals Under Section 3021(a) of the Energy Policy Act of 
                    1992 (Pub. L. 102-486) (JUN 1996)

    (a) Definition.--Energy Policy Act target groups, as used in this 
provision means:
    (1) An institution of higher education that meets the criteria of 34 
CFR 600.4(a) and has a student enrollment that consists of at least 20 
percent:
    (i) Hispanic Americans, i.e., students whose origins are in Mexico, 
Puerto Rico, Cuba, or Central or South America, or any combination 
thereof, or
    (ii) Native Americans, i.e., American Indians, Eskimos, Aleuts, and 
Native Hawaiians, or any combination thereof;
    (2) Institutions of higher learning determined by the Secretary of 
Education to be Historically Black Colleges and Universities pursuant to 
34 CFR 608.2; and
    (3) Small business concerns, as defined under section 3 of the Small 
Business Act (15 U.S.C. 632), that are owned and controlled by 
individuals who are both socially and economically disadvantaged within 
the meaning of section 8(d) of the Small Business Act (15 U.S.C. 637(d)) 
or by a woman or women.
    (b) Section 3021 of the Energy Policy Act (Pub. L. 102-486) 
establishes a goal of award of 10 percent of the contract dollar value 
for prime and subcontract Energy Policy Act awards to Energy Policy Act 
target groups.
    (c) The offeror, if other than one of the three groups specified in 
paragraph (a) of this clause, shall submit, as part of its business 
management proposal or, if this solicitation requires the submission of 
a Small, Small Disadvantaged and Women-Owned Subcontracting Plan, then 
as part of that plan, unless otherwise stated in the proposal 
preparation instructions, individual subcontracting goals for each of 
the three Energy Policy Act target groups. Individual goals shall be 
expressed in terms of a percentage of the offeror's proposed contract 
dollar value. In addition, the offeror shall provide a description of 
the nature of the effort to be performed by each of the three groups, 
and, if possible, the identity of the contemplated subcontractor(s).
    (d) Unless otherwise stated, such goals shall be considered in the 
evaluation of the Business Management Proposal as discussed in Section M 
of this solicitation or, if applicable, as part of the evaluation of the 
Small, Small Disadvantaged and Women-Owned Subcontracting Plan.

                           (End of provision)

[60 FR 22301, May 5, 1995, as amended at 61 FR 21977, May 13, 1996; 61 
FR 30823, June 18, 1996]



952.226-71  Utilization of Energy Policy Act target entities.

    As prescribed in 926.7007(b), insert the following clause:

       Utilization of Energy Policy Act Target Entities (JUN 1996)

    (a) Definition.--Energy Policy Act target groups, as used in this 
provision means:
    (1) An institution of higher education that meets the requirements 
of 34 CFR 600.4(a) and has a student enrollment that consists of at 
least 20 percent:
    (i) Hispanic Americans, i.e., students whose origins are in Mexico, 
Puerto Rico, Cuba, or Central or South America, or any combination 
thereof, or
    (ii) Native Americans, i.e., American Indians, Eskimos, Aleuts, and 
Native Hawaiians, or any combination thereof;
    (2) Institutions of higher learning determined to be Historically 
Black Colleges and Universities by the Secretary of Education pursuant 
to 34 CFR 608.2; and
    (3) Small business concerns, as defined under section 3 of the Small 
Business Act (15 U.S.C. 632), that are owned and controlled by 
individuals who are both socially and economically disadvantaged within 
the meaning of section 8(d) of the Small Business Act (15 U.S.C. 637(d)) 
or by a woman or women.
    (b) Obligation. In addition to its obligations under the clause of 
this contract entitled Utilization of Small Business, Small 
Disadvantaged and Women-Owned Small Business Concerns, the contractor, 
in performance of this contract, agrees to provide its

[[Page 373]]

best efforts to competitively award subcontracts to entities from among 
the Energy Policy Act target groups.

                             (End of clause)

[60 FR 22301, May 5, 1995, as amended at 61 FR 21977, May 13, 1996; 61 
FR 30823, June 18, 1996]



952.226-72  Energy Policy Act subcontracting goals and reporting requirements.

    As prescribed in 926.7007(c), insert the following clause:

 Energy Policy Act Subcontracting Goals and Reporting Requirements (JUN 
                                  1996)

    (a) Definition.--Energy Policy Act target groups, as used in this 
provision means:
    (1) An institution of higher education that meets the requirements 
of 34 CFR 600.4(a), and has a student enrollment that consists of at 
least 20 percent:
    (i) Hispanic Americans, i.e., students whose origins are in Mexico, 
Puerto Rico, Cuba, or Central or South America, or any combination 
thereof, or
    (ii) Native Americans, i.e., American Indians, Eskimos, Aleuts, and 
Native Hawaiians, or any combination thereof;
    (2) Institutions of higher learning determined to be Historically 
Black Colleges and Universities by the Secretary of Education pursuant 
to 34 CFR 608.2; and
    (3) Small business concerns, as defined under section 3 of the Small 
Business Act (15 U.S.C. 632), that are owned and controlled by 
individuals who are both socially and economically disadvantaged within 
the meaning of section 8(d) of the Small Business Act (15 U.S.C. 637(d)) 
or by a woman or women.
    (b) Goals.--The contractor, in performance of this contract, agrees 
to provide its best efforts to award subcontracts to the following 
classes of entities:
    (1) Small business concerns controlled by socially and economically 
disadvantaged individuals or by women: * * * percent;
    (2) Historically Black colleges and universities: * * * percent;
    (3) Colleges or universities having a student body in which more 
than 20 percent of the students are Hispanic Americans or Native 
Americans: * * * percent.
    [* * * These goals are stated in a percentage reflecting the 
relationship of estimated award value of subcontracts to the value of 
this contract and appear elsewhere in this contract.]
    (c) Reporting requirements. (1) The contractor agrees to report, on 
an annual Federal Government fiscal year basis, its progress against the 
goals by providing the actual annual dollar value of subcontract 
payments for the preceding 12-month period, and the relationship of 
those payments to the incurred contract costs for the same period. 
Reports submitted pursuant to this clause must be received by the 
contracting officer (or designee) not later than 45 days after the end 
of the reporting period.
    (2) If the contract includes reporting requirements under FAR 
52.219-9, Small, Small Disadvantaged and Women-Owned Subcontracting 
Plan, the contractor's progress against the goals stated in paragraph 
(b) of this clause shall be included as an addendum to Standard Form 
(SF) 294, Subcontracting Report for Individual Contracts, and/or SF 295, 
Summary Subcontract Report, as applicable, for the period that 
corresponds to the end of the Federal Government fiscal year.

                             (End of clause)

[60 FR 22302, May 5, 1995, as amended at 61 FR 21977, May 13, 1996; 61 
FR 30823, June 18, 1996]



952.226-73  Energy Policy Act target group certification.

    As prescribed in 926.7007(d), insert the following provision:

         Energy Policy Act Target Group Certification (SEP 1997)

    (a) Certification.--The offeror is:
    (1) ____ An institution of higher education that meets the 
requirements of 34 CFR 600.4(a), and has a student enrollment that 
consists of at least 20 percent:
    (i) Hispanic Americans, i.e., students whose origins are in Mexico, 
Puerto Rico, Cuba, or Central or South America, or any combination 
thereof, or
    (ii) Native Americans, i.e., American Indians, Eskimos, Aleuts, and 
Native Hawaiians, or any combination thereof;
    (2) ____ An institution of higher learning determined to be a 
Historically Black College and University by the Secretary of Education 
pursuant to 34 CFR 608.2; or
    (3) ____ A small business concern, as defined under section 3 of the 
Small Business Act (15 U.S.C. 632), that is owned and controlled by 
individuals who are both socially and economically disadvantaged within 
the meaning of section 8(d) of the Small Business Act (15 U.S.C. 637(d)) 
or by a woman or women.
    (b) By submission of an offer, the offeror agrees to provide to the 
Contracting Officer, upon request, evidence satisfactory to the 
contracting officer that the offeror is an entity from the Energy Policy 
Act target group identified.

(End of provision)
[60 FR 22302, May 5, 1995; 61 FR 30823, June 18, 1996, as amended at 62 
FR 42074, Aug. 5, 1997]

[[Page 374]]



952.226-74  Displaced employee hiring preference.

    As prescribed in 48 CFR (DEAR) 926.7104, insert the following 
clause.

            Displaced Employee Hiring Preference (June 1997)

    (a) Definition.
    Eligible employee means a current or former employee of a contractor 
or subcontractor employed at a Department of Energy Defense Nuclear 
Facility (1) whose position of employment has been, or will be, 
involuntarily terminated (except if terminated for cause), (2) who has 
also met the eligibility criteria contained in the Department of Energy 
guidance for contractor work force restructuring, as may be amended or 
supplemented from time to time, and (3) who is qualified for a 
particular job vacancy with the Department or one of its contractors 
with respect to work under its contract with the Department at the time 
the particular position is available.
    (b) Consistent with Department of Energy guidance for contractor 
work force restructuring, as may be amended or supplemented from time to 
time, the contractor agrees that it will provide a preference in hiring 
to an eligible employee to the extent practicable for work performed 
under this contract.
    (c) The requirements of this clause shall be included in 
subcontracts at any tier (except for subcontracts for commercial items 
pursuant to 41 U.S.C. 403) expected to exceed $500,000.
[62 FR 34862, June 27, 1997]



952.227  Provisions and clauses related to patents, technical data and copyrights.



952.227-9  Refund of royalties.

    As prescribed in 927.206-2, insert the following clause:

                     Refund of Royalties (Mar 1995)

    (a) The contract price includes certain amounts for royalties 
payable by the Contractor or subcontractors or both, which amounts have 
been reported to the Contracting Officer.
    (b) The term royalties as used in this clause refers to any costs or 
charges in the nature of royalties, license fees, patent or license 
amortization costs, or the like, for the use of or for rights in patents 
and patent applications in connection with performing this contract or 
any subcontract here-under. The term also includes any costs or charges 
associated with the access to, use of, or other right pertaining to data 
that is represented to be proprietary and is related to the performance 
of this contract or the copying of such data or data that is 
copyrighted.
    (c) The Contractor shall furnish to the Contracting Officer, before 
final payment under this contract, a statement of royalties paid or 
required to be paid in connection with performing this contract and 
subcontracts hereunder together with the reasons.
    (d) The Contractor will be compensated for royalties reported under 
paragraph (c) of this clause, only to the extent that such royalties 
were included in the contract price and are determined by the 
Contracting Officer to be properly chargeable to the Government and 
allocable to the contract. To the extent that any royalties that are 
included in the contract price are not, in fact, paid by the Contractor 
or are determined by the Contracting Officer not to be properly 
chargeable to the government and allocable to the contract, the contract 
price shall be reduced. Repayment or credit to the Government shall be 
made as the Contracting Officer directs. The approval by DOE of any 
individual payments or royalties shall not prevent the Government from 
contesting at any time the enforceability, validity, scope of, or title 
to, any patent or the proprietary nature of data pursuant to which a 
royalty or other payment is to be or has been made.
    (e) If, at any time within 3 years after final payment under this 
contract, the Contractor for any reason is relieved in whole or in part 
from the payment of the royalties included in the final contract price 
as adjusted pursuant to paragraph (d) of this clause, the Contractor 
shall promptly notify the Contracting Officer of that fact and shall 
reimburse the Government in a corresponding amount.
    (f) The substance of this clause, including this paragraph (f), 
shall be included in any subcontract in which the amount of royalties 
reported during negotiation of the subcontract exceeds $250.

                             (End of clause)

[60 FR 11817, Mar. 2, 1995]



952.227-11  Patent rights--retention by the contractor (short form).

    As prescribed in 927.303(a), insert the following clause:

   Patent Rights--Retention by the Contractor (Short Form) (Mar 1995)

    (a) Definitions.
    (1) Invention means any invention or discovery which is or may be 
patentable or otherwise protectable under title 35 of the United States 
Code, or any novel variety of plant which is or may be protected under 
the Plant Variety Protection Act (7 U.S.C. 2321, et seq.).

[[Page 375]]

    (2) Made when used in relation to any invention means the conception 
of first actual reduction to practice of such invention.
    (3) Nonprofit organization means a university or other institution 
of higher education or an organization of the type described in section 
501(c)(3) of the Internal Revenue Code of 1954 (26 U.S.C. 501(c)) and 
exempt from taxation under section 501(a) of the Internal Revenue Code 
(26 U.S.C. 501(a)) or any nonprofit scientific or educational 
organization qualified under a state nonprofit organization statute.
    (4) Practical application means to manufacture, in the case of a 
composition or product; to practice, in the case of a process or method; 
or to operate, in the case of a machine or system; and, in each case, 
under such conditions as to establish that the invention is being 
utilized and that its benefits are, to the extent permitted by law or 
Government regulations, available to the public on reasonable terms.
    (5) Small business firm means a small business concern as defined at 
section 2 of Public Law 85-536 (15 U.S.C. 632) and implementing 
regulations of the Administrator of the Small Business Administration. 
For the purpose of this clause, the size standards for small business 
concerns involved in Government procurement and subcontracting at 13 CFR 
121.3-8 and 13 CFR 121.3-12, respectively, will be used.
    (6) Subject invention means any invention of the contractor 
conceived or first actually reduced to practice in the performance of 
work under this contract, provided that in the case of a variety of 
plant, the date of determination (as defined in section 41(d) of the 
Plant Variety Protection Act, 7 U.S.C. 2401(d)) must also occur during 
the period of contract performance.
    (7) Agency licensing regulations and agency regulations concerning 
the licensing of Government-owned inventions mean the Department of 
Energy patent licensing regulations at 10 CFR part 781.
    (b) Allocation of principal rights. The Contractor may retain the 
entire right, title, and interest throughout the world to each subject 
invention subject to the provisions of this clause and 35 U.S.C. 203. 
With respect to any subject invention in which the Contractor retains 
title, the Federal Government shall have a nonexclusive, 
nontransferable, irrevocable, paid-up license to practice or have 
practiced for or on behalf of the United States the subject invention 
throughout the world.
    (c) Invention disclosure, election of title, and filing of patent 
application by Contractor. (1) The Contractor will disclose each subject 
invention to the Department of Energy (DOE) within 2 months after the 
inventor discloses it in writing to Contractor personnel responsible for 
patent matters. The disclosure to DOE shall be in the form of a written 
report and shall identify the contract under which the invention was 
made and the inventor(s). It shall be sufficiently complete in technical 
detail to convey a clear understanding to the extent known at the time 
of the disclosure, of the nature, purpose, operation, and the physical, 
chemical, biological or electrical characteristics of the invention. The 
disclosure shall also identify any publication, on sale or public use of 
the invention and whether a manuscript describing the invention has been 
submitted for publication and, if so, whether it has been accepted for 
publication at the time of disclosure. In addition, after disclosure to 
the DOE, the Contractor will promptly notify that agency of the 
acceptance of any manuscript describing the invention for publication or 
of any on sale or public use planned by the Contractor.
    (2) The Contractor will elect in writing whether or not to retain 
title to any such invention by notifying DOE within 2 years of 
disclosure to DOE. However, in any case where publication, on sale or 
public use has initiated the l-year statutory period wherein valid 
patent protection can still be obtained in the United States, the period 
for election of title may be shortened by DOE to a date that is no more 
than 60 days prior to the end of the statutory period.
    (3) The Contractor will file its initial patent application on a 
subject invention to which it elects to retain title within 1 year after 
election of title or, if earlier, prior to the end of any statutory 
period wherein valid patent protection can be obtained in the United 
States after a publication, on sale, or public use. The Contractor will 
file patent applications in additional countries or international patent 
offices within either 10 months of the corresponding initial patent 
application or 6 months from the date permission is granted by the 
Commissioner of Patents and Trademarks to file foreign patent 
applications where such filing has been prohibited by a Secrecy Order.
    (4) Requests for extension of the time for disclosure, election, and 
filing under subparagraphs (c)(l), (2), and (3) of this clause may, at 
the discretion of the agency, be granted.
    (d) Conditions when the Government may obtain title. The Contractor 
will convey to the Federal agency, upon written request, title to any 
subject invention--
    (1) If the Contractor fails to disclose or elect title to the 
subject invention within the times specified in paragraph (c) of this 
clause, or elects not to retain title; provided, that DOE may only 
request title within 60 days after learning of the failure of the 
Contractor to disclose or elect within the specified times.
    (2) In those countries in which the Contractor fails to file patent 
applications within the times specified in paragraph (c) of this

[[Page 376]]

clause; provided, however, that if the Contractor has filed a patent 
application in a country after the times specified in paragraph (c) of 
this clause, but prior to its receipt of the written request of the 
Federal agency, the Contractor shall continue to retain title in that 
country.
    (3) In any country in which the Contractor decides not to continue 
the prosecution of any application for, to pay the maintenance fees on, 
or defend in reexamination or opposition proceeding on, a patent on a 
subject invention.
    (e) Minimum rights to Contractor and protection of the Contractor 
right to file. (1) The Contractor will retain a nonexclusive royalty-
free license throughout the world in each subject invention to which the 
Government obtains title, except if the Contractor fails to disclose the 
invention within the times specified in paragraph (c) of this clause. 
The Contractor's license extends to its domestic subsidiary and 
affiliates, if any, within the corporate structure of which the 
Contractor is a party and includes the right to grant sublicenses of the 
same scope to the extent the Contractor was legally obligated to do so 
at the time the contract was awarded. The license is transferable only 
with the approval of the Federal agency, except when transferred to the 
successor of that part of the Contractor's business to which the 
invention pertains.
    (2) The Contractor's domestic license may be revoked or modified by 
DOE to the extent necessary to achieve expeditious practical application 
of subject invention pursuant to an application for an exclusive license 
submitted in accordance with applicable provisions at 37 CFR part 404 
and agency licensing regulations. This license will not be revoked in 
that field of use or the geographical areas in which the Contractor has 
achieved practical application and continues to make the benefits of the 
invention reasonably accessible to the public. The license in any 
foreign country may be revoked or modified at the discretion of DOE to 
the extent the Contractor, its licensees, or the domestic subsidiaries 
or affiliates have failed to achieve practical application in that 
foreign country.
    (3) Before revocation or modification of the license, DOE will 
furnish the Contractor a written notice of its intention to revoke or 
modify the license, and the Contractor will be allowed 30 days (or such 
other time as may be authorized by DOE for good cause shown by the 
Contractor) after the notice to show cause why the license should not be 
revoked or modified. The Contractor has the right to appeal, in 
accordance with applicable regulations in 37 CFR part 404 and agency 
regulations concerning the licensing of Government owned inventions, any 
decision concerning the revocation or modification of the license.
    (f) Contractor action to protect the Government's interest. (1) The 
Contractor agrees to execute or to have executed and promptly deliver to 
DOE all instruments necessary to (i) establish or confirm the rights the 
Government has throughout the world in those subject inventions to which 
the Contractor elects to retain title, and (ii) convey title to DOE when 
requested under paragraph (d) of this clause and to enable the 
government to obtain patent protection throughout the world in that 
subject invention.
    (2) The Contractor agrees to require, by written agreement, its 
employees, other than clerical and nontechnical employees, to disclose 
promptly in writing to personnel identified as responsible for the 
administration of patent matters and in a format suggested by the 
Contractor each subject invention made under contract in order that the 
Contractor can comply with the disclosure provisions of paragraph (c) of 
this clause, and to execute all papers necessary to file patent 
applications on subject inventions and to establish the Government's 
rights in the subject inventions. This disclosure format should require, 
as a minimum, the information required by subparagraph (c)(1) of this 
clause. The Contractor shall instruct such employees, through employee 
agreements or other suitable educational programs, on the importance of 
reporting inventions in sufficient time to permit the filing of patent 
applications prior to U.S. or foreign statutory bars.
    (3) The Contractor will notify DOE of any decision not to continue 
the prosecution of a patent application, pay maintenance fees, or defend 
in a reexamination or opposition proceeding on a patent, in any country, 
not less than 30 days before the expiration of the response period 
required by the relevant patent office.
    (4) The Contractor agrees to include, within the specification of 
any United States patent application and any patent issuing thereon 
covering a subject invention, the following statement, ``This invention 
was made with Government support under (identify the contract) awarded 
by the United States Department of Energy. The Government has certain 
rights in the invention.''
    (g) Subcontracts. (1) The Contractor will include this clause, 
suitably modified to identify the parties, in all subcontracts, 
regardless of tier, for experimental, developmental, or research work to 
be performed by a small business firm or domestic nonprofit 
organization. The subcontractor will retain all rights provided for the 
Contractor in this clause, and the Contractor will not, as part of the 
consideration for awarding the subcontract, obtain rights in the 
subcontractor's subject inventions.
    (2) The contractor shall include in all other subcontracts, 
regardless of tier, for experimental, developmental, demonstration, or

[[Page 377]]

research work the patent rights clause at 952.227-13.
    (3) In the case of subcontracts, at any tier, DOE, subcontractor, 
and the Contractor agree that the mutual obligations of the parties 
created by this clause constitute a contract between the subcontractor 
and DOE with respect to the matters covered by the clause; provided, 
however, that nothing in this paragraph is intended to confer any 
jurisdiction under the Contract Disputes Act in connection with 
proceedings under paragraph (j) of this clause.
    (h) Reporting on utilization of subject inventions. The Contractor 
agrees to submit, on request, periodic reports no more frequently than 
annually on the utilization of a subject invention or on efforts at 
obtaining such utilization that are being made by the Contractor or its 
licensees or assignees. Such reports shall include information regarding 
the status of development, date of first commercial sale or use, gross 
royalties received, by the Contractor, and such other data and 
information as DOE may reasonably specify. The Contractor also agrees to 
provide additional reports as may be requested by DOE in connection with 
any march-in proceeding undertaken by that agency in accordance with 
paragraph (j) of this clause. As required by 35 U.S.C. 202(c)(5), DOE 
agrees it will not disclose such information to persons outside the 
Government without permission of the Contractor.
    (i) Preference for United States industry. Notwithstanding any other 
provision of this clause, the Contractor agrees that neither it nor any 
assignee will grant to any person the exclusive right to use or sell any 
subject invention in the United States unless such person agrees that 
any product embodying the subject invention or produced through the use 
of the subject invention will be manufactured substantially in the 
United States. However, in individual cases, the requirement for such an 
agreement may be waived by DOE upon a showing by the Contractor or its 
assignee that reasonable but unsuccessful efforts have been made to 
grant licenses on similar terms to potential licensees that would be 
likely to manufacture substantially in the United States or that under 
the circumstances domestic manufacture is not commercially feasible.
    (j) March-in rights. The Contractor agrees that, with respect to any 
subject invention in which it has acquired title, DOE has the right in 
accordance with the procedures in 37 CFR 401.6 and any supplemental 
regulations of the agency to require the Contractor, an assignee or 
exclusive licensee of a subject invention to grant a nonexclusive, 
partially exclusive, or exclusive license in any field of use to a 
responsible applicant or applicants, upon terms that are reasonable 
under the circumstances, and, if the Contractor, assignee, or exclusive 
licensee refuses such a request, DOE has the right to grant such a 
license itself if DOE determines that--
    (1) Such action is necessary because the Contractor or assignee has 
not taken, or is not expected to take within a reasonable time, 
effective steps to achieve practical application of the subject 
invention in such field of use;
    (2) Such action is necessary to alleviate health or safety needs 
which are not reasonably satisfied by the Contractor, assignee, or their 
licensees;
    (3) Such action is necessary to meet requirements for public use 
specified by Federal regulations and such requirements are not 
reasonably satisfied by the Contractor, assignee, or licensees; or
    (4) Such action is necessary because the agreement required by 
paragraph (i) of this clause has not been obtained or waived or because 
a licensee of the exclusive right to use or sell any subject invention 
in the United States is in breach of such agreement.
    (k) Special provisions for contracts with nonprofit organizations. 
If the Contractor is a nonprofit organization, it agrees that--
    (1) Rights to a subject invention in the United States may not be 
assigned without the approval of the Federal agency, except where such 
assignment is made to an organization which has as one of its primary 
functions the management of inventions; provided, that such assignee 
will be subject to the same provisions as the Contractor;
    (2) The Contractor will share royalties collected on a subject 
invention with the inventor, including Federal employee co-inventors 
(when DOE deems it appropriate) when the subject invention is assigned 
in accordance with 35 U.S.C. 202(e) and 37 CFR 401.10;
    (3) The balance of any royalties or income earned by the Contractor 
with respect to subject inventions, after payment of expenses (including 
payments to inventors) incidental to the administration of subject 
inventions will be utilized for the support of scientific research or 
education; and
    (4) It will make efforts that are reasonable under the circumstances 
to attract licensees of subject inventions that are small business 
firms, and that it will give a preference to a small business firm when 
licensing a subject invention if the Contractor determines that the 
small business firm has a plan or proposal for marketing the invention 
which, if executed, is equally as likely to bring the invention to 
practical application as any plans or proposals from applicants that are 
not small business firms; provided, that the Contractor is also 
satisfied that the small business firm has the capability and resources 
to carry out its plan or proposal. The decision whether to give a 
preference in any specific case will be at the discretion of the 
contractor. However, the Contractor agrees that the

[[Page 378]]

Secretary of Commerce may review the Contractor's licensing program and 
decisions regarding small business applicants, and the Contractor will 
negotiate changes to its licensing policies, procedures, or practices 
with the Secretary of Commerce when that Secretary's review discloses 
that the Contractor could take reasonable steps to more effectively 
implement the requirements of this subparagraph (k)(4).
    (l) Communications. (1) The contractor shall direct any 
notification, disclosure, or request to DOE provided for in this clause 
to the DOE patent counsel assisting the DOE contracting activity, with a 
copy of the communication to the Contracting Officer.
    (2) Each exercise of discretion or decision provided for in this 
clause, except subparagraph (k)(4), is reserved for the DOE Patent 
Counsel and is not a claim or dispute and is not subject to the Contract 
Disputes Act of 1978.
    (3) Upon request of the DOE Patent Counsel or the contracting 
officer, the contractor shall provide any or all of the following:
    (i) A copy of the patent application, filing date, serial number and 
title, patent number, and issue date for any subject invention in any 
country in which the contractor has applied for a patent;
    (ii) A report, not more often than annually, summarizing all subject 
inventions which were disclosed to DOE individually during the reporting 
period specified; or
    (iii) A report, prior to closeout of the contract, listing all 
subject inventions or stating that there were none.

                             (End of clause)

[60 FR 11817, Mar. 2, 1995]



952.227-13  Patent rights--acquisition by the Government.

    As prescribed at 927.303(c), insert the following clause:

         Patent Rights--Acquisition by the Government (SEP 1997)

    (a) Definitions.T1
    Invention, as used in this clause, means any invention or discovery 
which is or may be patentable or otherwise protectable under title 35 of 
the United States Code or any novel variety of plant that is or may be 
protectable under the Plant Variety Protection Act (7 U.S.C. 2321, et 
seq.).
    Practical application, as used in this clause, means to manufacture, 
in the case of a composition or product; to practice, in the case of a 
process or method; or to operate, in the case of a machine or system; 
and, in each case, under such conditions as to establish that the 
invention is being utilized and that its benefits are, to the extent 
permitted by law or Government regulations, available to the public on 
reasonable terms.
    Subject invention, as used in this clause, means any invention of 
the Contractor conceived or first actually reduced to practice in the 
course of or under this contract.
    Patent Counsel, as used in this clause, means the Department of 
Energy Patent Counsel assisting the procuring activity.
    DOE patent waiver regulations, as used in this clause, means the 
Department of Energy patent waiver regulations in effect on the date of 
award of this contract.
    Agency licensing regulations and applicable agency licensing 
regulations, as used in this clause, mean the Department of Energy 
patent licensing regulations at 10 CFR part 781.
    (b) Allocations of principal rights. (1) Assignment to the 
Government. The Contractor agrees to assign to the Government the entire 
right, title, and interest throughout the world in and to each subject 
invention, except to the extent that rights are retained by the 
Contractor under subparagraph (b)(2) and paragraph (d) of this clause.
    (2) Greater rights determinations. (i) The Contractor, or an 
employee-inventor after consultation with the Contractor, may request 
greater rights than the nonexclusive license and the foreign patent 
rights provided in paragraph (d) of this clause on identified inventions 
in accordance with the DOE patent waiver regulations. A request for a 
determination of whether the Contractor or the employee-inventor is 
entitled to acquire such greater rights must be submitted to the Patent 
Counsel with a copy to the Contracting Officer at the time of the first 
disclosure of the invention pursuant to subparagraph (e)(2) of this 
clause, or not later than 8 months thereafter, unless a longer period is 
authorized in writing by the Contracting Officer for good cause shown in 
writing by the Contractor. Each determination of greater rights under 
this contract shall be subject to paragraph (c) of this clause, unless 
otherwise provided in the greater rights determination, and to the 
reservations and conditions deemed to be appropriate by the Secretary of 
Energy or designee.
    (ii) Within two (2) months after the filing of a patent application, 
the Contractor shall provide the filing date, serial number and title, a 
copy of the patent application (including an English-language version if 
filed in a language other than English), and, promptly upon issuance of 
a patent, provide the patent number and issue date for any subject 
invention in any country for which the Contractor has been granted title 
or the right to file and prosecute on behalf of the United States by the 
Department of Energy.
    (iii) Not less than thirty (30) days before the expiration of the 
response period for any action required by the Patent and Trademark 
Office, notify the Patent Counsel of

[[Page 379]]

any decision not to continue prosecution of the application.
    (iv) Upon request, the Contractor shall furnish the Government an 
irrevocable power to inspect and make copies of the patent application 
file.
    (c) Minimum rights acquired by the Government. (1) With respect to 
each subject invention to which the Department of Energy grants the 
Contractor principal or exclusive rights, the Contractor agrees as 
follows:
    (i) The Contractor hereby grants to the Government a nonexclusive, 
nontransferable, irrevocable, paid-up license to practice or have 
practiced each subject invention throughout the world by or on behalf of 
the Government of the United States (including any Government agency).
    (ii) The Contractor agrees that with respect to any subject 
invention in which DOE has granted it title, DOE has the right in 
accordance with the procedures in the DOE patent waiver regulations to 
require the Contractor, an assignee, or exclusive licensee of a subject 
invention to grant a nonexclusive, partially exclusive, or exclusive 
license in any field of use to a responsible applicant or applicants, 
upon terms that are reasonable under the circumstances, and if the 
Contractor, assignee, or exclusive licensee refuses such a request, DOE 
has the right to grant such a license itself if it determines that--
    (A) Such action is necessary because the Contractor or assignee has 
not taken, or is not expected to take within a reasonable time, 
effective steps to achieve practical application of the subject 
invention in such field of use;
    (B) Such action is necessary to alleviate health or safety needs 
which are not reasonably satisfied by the Contractor, assignee, or their 
licensees;
    (C) Such action is necessary to meet requirements for public use 
specified by Federal regulations and such requirements are not 
reasonably satisfied by the Contractor, assignee, or licensees; or
    (D) Such action is necessary because the agreement required by 
paragraph (i) of this clause has neither been obtained nor waived or 
because a licensee of the exclusive right to use or sell any subject 
invention in the United States is in breach of such agreement.
    (iii) The Contractor agrees to submit on request periodic reports no 
more frequently than annually on the utilization of a subject invention 
or on efforts at obtaining such utilization of a subject invention or on 
efforts at obtaining such utilization that are being made by the 
Contractor or its licensees or assignees. Such reports shall include 
information regarding the status of development, date of first 
commercial sale or use, gross royalties received by the Contractor, and 
such other data and information as DOE may reasonably specify. The 
Contractor also agrees to provide additional reports as may be requested 
by DOE in connection with any march-in proceedings undertaken by that 
agency in accordance with subparagraph (c)(1)(ii) of this clause. To the 
extent data or information supplied under this section is considered by 
the Contractor, its licensee, or assignee to be privileged and 
confidential and is so marked, the Department of Energy agrees that, to 
the extent permitted by law, it will not disclose such information to 
persons outside the Government.
    (iv) The Contractor agrees, when licensing a subject invention, to 
arrange to avoid royalty charges on acquisitions involving Government 
funds, including funds derived through a Military Assistance Program of 
the Government or otherwise derived through the Government, to refund 
any amounts received as royalty charges on a subject invention in 
acquisitions for, or on behalf of, the Government, and to provide for 
such refund in any instrument transferring rights in the invention to 
any party.
    (v) The Contractor agrees to provide for the Government's paid-up 
license pursuant to subparagraph (c)(1)(i) of this clause in any 
instrument transferring rights in a subject invention and to provide for 
the granting of licenses as required by subparagraph (c)(1)(ii) of this 
clause, and for the reporting of utilization information as required by 
subparagraph (c)(1)(iii) of this clause, whenever the instrument 
transfers principal or exclusive rights in a subject invention.
    (2) Nothing contained in this paragraph (c) shall be deemed to grant 
to the Government any rights with respect to any invention other than a 
subject invention.
    (d) Minimum rights to the Contractor. (1) The Contractor is hereby 
granted a revocable, nonexclusive, royalty-free license in each patent 
application filed in any country on a subject invention and any 
resulting patent in which the Government obtains title, unless the 
Contractor fails to disclose the subject invention within the times 
specified in subparagraph (e)(2) of this clause. The Contractor's 
license extends to its domestic subsidiaries and affiliates, if any, 
within the corporate structure of which the Contractor is a part and 
includes the right to grant sublicenses of the same scope to the extent 
the Contractor was legally obligated to do so at the time the contract 
was awarded. The license is transferable only with the approval of DOE 
except when transferred to the successor of that part of the 
Contractor's business to which the invention pertains.
    (2) The Contractor's domestic license may be revoked or modified by 
DOE to the extent necessary to achieve expeditious practical application 
of the subject invention pursuant to an application for an exclusive 
license

[[Page 380]]

submitted in accordance with applicable provisions in 37 CFR part 404 
and agency licensing regulations. This license will not be revoked in 
that field of use or the geographical areas in which the Contractor has 
achieved practical applications and continues to make the benefits of 
the invention reasonably accessible to the public. The license in any 
foreign country may be revoked or modified at the discretion of DOE to 
the extent the Contractor, its licensees, or its domestic subsidiaries 
or affiliates have failed to achieve practical application in that 
foreign country.
    (3) Before revocation or modification of the license, DOE will 
furnish the Contractor a written notice of its intention to revoke or 
modify the license, and the Contractor will be allowed 30 days (or such 
other time as may be authorized by DOE for good cause shown by the 
Contractor) after the notice to show cause why the license should not be 
revoked or modified. The Contractor has the right to appeal, in 
accordance with applicable agency licensing regulations and 37 CFR part 
404 concerning the licensing of Government-owned inventions, any 
decision concerning the revocation or modification of its license.
    (4) The Contractor may request the right to acquire patent rights to 
a subject invention in any foreign country where the Government has 
elected not to secure such rights, subject to the conditions in 
subparagraphs (d)(4)(i) through (d)(4)(vii) of this clause. Such request 
must be made in writing to the Patent Counsel as part of the disclosure 
required by subparagraph (e)(2) of this clause, with a copy to the DOE 
Contracting Officer. DOE approval, if given, will be based on a 
determination that this would best serve the national interest.
    (i) The recipient of such rights, when specifically requested by 
DOE, and three years after issuance of a foreign patent disclosing the 
subject invention, shall furnish DOE a report stating:
    (A) The commercial use that is being made, or is intended to be 
made, of said invention, and
    (B) The steps taken to bring the invention to the point of practical 
application or to make the invention available for licensing.
    (ii) The Government shall retain at least an irrevocable, 
nonexclusive, paid-up license to make, use, and sell the invention 
throughout the world by or on behalf of the Government (including any 
Government agency) and States and domestic municipal governments, unless 
the Secretary of Energy or designee determines that it would not be in 
the public interest to acquire the license for the States and domestic 
municipal governments.
    (iii) If noted elsewhere in this contract as a condition of the 
grant of an advance waiver of the Government's title to inventions under 
this contract, or, if no advance waiver was granted but a waiver of the 
Government's title to an identified invention is granted pursuant to 
subparagraph (b)(2) of this clause upon a determination by the Secretary 
of Energy that it is in the Government's best interest, this license 
shall include the right of the Government to sublicense foreign 
governments pursuant to any existing or future treaty or agreement with 
such foreign governments.
    (iv) Subject to the rights granted in subparagraphs (d)(1), (2), and 
(3) of this clause, the Secretary of Energy or designee shall have the 
right to terminate the foreign patent rights granted in this 
subparagraph (d)(4) in whole or in part unless the recipient of such 
rights demonstrates to the satisfaction of the Secretary of Energy or 
designee that effective steps necessary to accomplish substantial 
utilization of the invention have been taken or within a reasonable time 
will be taken.
    (v) Subject to the rights granted in subparagraphs (d)(1), (2), and 
(3) of this clause, the Secretary of Energy or designee shall have the 
right, commencing four years after foreign patent rights are accorded 
under this subparagraph (d)(4), to require the granting of a 
nonexclusive or partially exclusive license to a responsible applicant 
or applicants, upon terms reasonable under the circumstances, and in 
appropriate circumstances to terminate said foreign patent rights in 
whole or in part, following a hearing upon notice thereof to the public, 
upon a petition by an interested person justifying such hearing:
    (A) If the Secretary of Energy or designee determines, upon review 
of such material as he deems relevant, and after the recipient of such 
rights or other interested person has had the opportunity to provide 
such relevant and material information as the Secretary or designee may 
require, that such foreign patent rights have tended substantially to 
lessen competition or to result in undue market concentration in any 
section of the United States in any line of commerce to which the 
technology relates; or
    (B) Unless the recipient of such rights demonstrates to the 
satisfaction of the Secretary of Energy or designee at such hearing that 
the recipient has taken effective steps, or within a reasonable time 
thereafter is expected to take such steps, necessary to accomplish 
substantial utilization of the invention.
    (vi) If the contractor is to file a foreign patent application on a 
subject invention, the Government agrees, upon written request, to use 
its best efforts to withhold publication of such invention disclosures 
for such period of time as specified by Patent Counsel, but in no event 
shall the Government or its employees be liable for any publication 
thereof.

[[Page 381]]

    (vii) Subject to the license specified in subparagraphs (d) (1), 
(2), and (3) of this clause, the contractor or inventor agrees to convey 
to the Government, upon request, the entire right, title, and interest 
in any foreign country in which the contractor or inventor fails to have 
a patent application filed in a timely manner or decides not to continue 
prosecution or to pay any maintenance fees covering the invention. To 
avoid forfeiture of the patent application or patent, the contractor or 
inventor shall, not less than 60 days before the expiration period for 
any action required by any patent office, notify the Patent Counsel of 
such failure or decision, and deliver to the Patent Counsel, the 
executed instruments necessary for the conveyance specified in this 
paragraph.
    (e) Invention identification, disclosures, and reports. (1) The 
Contractor shall establish and maintain active and effective procedures 
to assure that subject inventions are promptly identified and disclosed 
to Contractor personnel responsible for patent matters within 6 months 
of conception and/or first actual reduction to practice, whichever 
occurs first in the performance of work under this contract. These 
procedures shall include the maintenance of laboratory notebooks or 
equivalent records and other records as are reasonably necessary to 
document the conception and/or the first actual reduction to practice of 
subject inventions, and records that show that the procedures for 
identifying and disclosing the inventions are followed. Upon request, 
the Contractor shall furnish the Contracting Officer a description of 
such procedures for evaluation and for determination as to their 
effectiveness.
    (2) The Contractor shall disclose each subject invention to the DOE 
Patent Counsel with a copy to the Contracting Officer within 2 months 
after the inventor discloses it in writing to Contractor personnel 
responsible for patent matters or, if earlier, within 6 months after the 
Contractor becomes aware that a subject invention has been made, but in 
any event before any on sale, public use, or publication of such 
invention known to the Contractor. The disclosure to DOE shall be in the 
form of a written report and shall identify the contract under which the 
invention was made and the inventor(s). It shall be sufficiently 
complete in technical detail to convey a clear understanding, to the 
extent known at the time of the disclosure, of the nature, purpose, 
operation, and physical, chemical, biological, or electrical 
characteristics of the invention. The disclosure shall also identify any 
publication, on sale, or public use of the invention and whether a 
manuscript describing the invention has been submitted for publication 
and, if so, whether it has been accepted for publication at the time of 
disclosure. In addition, after disclosure to DOE, the Contractor shall 
promptly notify Patent Counsel of the acceptance of any manuscript 
describing the invention for publication or of any on sale or public use 
planned by the Contractor. The report should also include any request 
for a greater rights determination in accordance with subparagraph 
(b)(2) of this clause. When an invention is disclosed to DOE under this 
paragraph, it shall be deemed to have been made in the manner specified 
in Sections (a)(1) and (a)(2) of 42 U.S.C. 5908, unless the Contractor 
contends in writing at the time the invention is disclosed that is was 
not so made.
    (3) The Contractor shall furnish the Contracting Officer the 
following:
    (i) Interim reports every 12 months (or such longer period as may be 
specified by the Contracting Officer) from the date of the contract, 
listing all subject inventions during that period, and including a 
statment that all subject inventions have been disclosed (or that there 
are not such inventions), and that such disclosure has been made in 
accordance with the procedures required by paragraph (e)(1) of this 
clause.
    (ii) A final report, within 3 months after completion of the 
contracted work listing all subject inventions or containing a statement 
that there were no such inventions, and listing all subcontracts at any 
tier containing a patent right clause or containing a statement that 
there were no such subcontracts.
    (4) The Contractor agrees to require, by written agreement, its 
employees, other than clerical and nontechnical employees, to disclose 
promptly in writing to personnel identified as responsible for the 
administration of patent matters and in a format suggested by the 
Contractor each subject invention made under contract in order that the 
Contractor can comply with the disclosure provisions of paragraph (c) of 
this clause, and to execute all papers necessary to file patent 
applications on subject inventions and to establish the Government's 
rights in the subject inventions. This disclosure format should require, 
as a minimum, the information required by subparagraph (e)(2) of this 
clause.
    (5) The Contractor agrees, subject to FAR 27.302(j), that the 
Government may duplicate and disclose subject invention disclosures and 
all other reports and papers furnished or required to be furnished 
pursuant to this clause.
    (f) Examination of records relating to inventions. (1) The 
Contracting Officer or any authorized representative shall, until 3 
years after final payment under this contract, have the right to examine 
any books (including laboratory notebooks), records, and documents of 
the Contractor relating to the conception or first actual reduction to 
practice of inventions in the same field of technology as the work under 
this contract to determine whether--

[[Page 382]]

    (i) Any such inventions are subject inventions;
    (ii) The Contractor has established and maintains the procedures 
required by subparagraphs (e) (1) and (4) of this clause;
    (iii) The Contractor and its inventors have complied with the 
procedures.
    (2) If the Contracting Officer learns of an unreported Contractor 
invention which the Contracting Officer believes may be a subject 
invention, the Contractor may be required to disclose the invention to 
DOE for a determination of ownership rights.
    (3) Any examination of records under this paragraph will be subject 
to appropriate conditions to protect the confidentiality of the 
information involved.
    (g) Withholding of payment (This paragraph does not apply to 
subcontracts).
    (1) Any time before final payment under this contract, the 
Contracting Officer may, in the Government's interest, withhold payment 
until a reserve not exceeding $50,000 or 5 percent of the amount of this 
contract, whichever is less, shall have been set aside if, in the 
Contracting Officer's opinion, the Contractor fails to--
    (i) Convey to the Government, using a DOE-approved form, the title 
and/or rights of the Government in each subject invention as required by 
this clause.
    (ii) Establish, maintain, and follow effective procedures for 
identifying and disclosing subject inventions pursuant to subparagraph 
(e)(1) of this clause;
    (iii) Disclose any subject invention pursuant to subparagraph (e)(2) 
of this clause;
    (iv) Deliver acceptable interim reports pursuant to subparagraph 
(e)(3)(i) of this clause; or
    (v) Provide the information regarding subcontracts pursuant to 
subparagraph (h)(4) of this clause.
    (2) Such reserve or balance shall be withheld until the Contracting 
Officer has determined that the Contractor has rectified whatever 
deficiencies exist and has delivered all reports, disclosures, and other 
information required by this clause.
    (3) Final payment under this contract shall not be made before the 
Contractor delivers to the Contracting Officer all disclosures of 
subject inventions required by subparagraph (e)(2) of this clause, and 
acceptable final report pursuant to subparagraph (e)(3)(ii) of this 
clause, and the Patent Counsel has issued a patent clearance 
certification to the Contracting Officer.
    (4) The Contracting Officer may decrease or increase the sums 
withheld up to the maximum authorized above. No amount shall be withheld 
under this paragraph while the amount specified by this paragraph is 
being withheld under other provisions of the contract. The withholding 
of any amount or the subsequent payment thereof shall not be construed 
as a waiver of any Government rights.
    (h) Subcontracts. (1) The contractor shall include the clause at 48 
CFR 952.227-11 (suitably modified to identify the parties) in all 
subcontracts, regardless of tier, for experimental, developmental, 
demonstration, or research work to be performed by a small business firm 
or domestic nonprofit organization, except where the work of the 
subcontract is subject to an Exceptional Circumstances Determination by 
DOE. In all other subcontracts, regardless of tier, for experimental, 
developmental, demonstration, or research work, the contractor shall 
include this clause (suitably modified to identify the parties). The 
contractor shall not, as part of the consideration for awarding the 
subcontract, obtain rights in the subcontractor's subject inventions.
    (2) In the event of a refusal by a prospective subcontractor to 
accept such a clause the Contractor--
    (i) Shall promptly submit a written notice to the Contracting 
Officer setting forth the subcontractor's reasons for such refusal and 
other pertinent information that may expedite disposition of the matter; 
and
    (ii) Shall not proceed with such subcontract without the written 
authorization of the Contracting Officer.
    (3) In the case of subcontracts at any tier, DOE, the subcontractor, 
and Contractor agree that the mutual obligations of the parties created 
by this clause constitute a contract between the subcontractor and DOE 
with respect to those matters covered by this clause.
    (4) The Contractor shall promptly notify the Contracting Officer in 
writing upon the award of any subcontract at any tier containing a 
patent rights clause by identifying the subcontractor, the applicable 
patent rights clause, the work to be performed under the subcontract, 
and the dates of award and estimated completion. Upon request of the 
Contracting Officer, the Contractor shall furnish a copy of such 
subcontract, and, no more frequently than annually, a listing of the 
subcontracts that have been awarded.
    (5) The contractor shall identify all subject inventions of the 
subcontractor of which it acquires knowledge in the performance of this 
contract and shall notify the Patent Counsel, with a copy to the 
contracting officer, promptly upon identification of the inventions.
    (i) Preference United States industry. Unless provided otherwise, no 
Contractor that receives title to any subject invention and no assignee 
of any such Contractor shall grant to any person the exclusive right to 
use or sell any subject invention in the United States unless such 
person agrees that any products embodying the subject invention will be 
manufactured substantially in the

[[Page 383]]

United States. However, in individual cases, the requirement may be 
waived by the Government upon a showing by the Contractor or assignee 
that reasonable but unsuccessful efforts have been made to grant 
licenses on similar terms to potential licensees that would be likely to 
manufacture substantially in the United States or that under the 
circumstances domestic manufacture is not commercially feasible.
    (j) Atomic energy. (1) No claim for pecuniary award of compensation 
under the provisions of the Atomic Energy Act of 1954, as amended, shall 
be asserted with respect to any invention or discovery made or conceived 
in the course of or under this contract.
    (2) Except as otherwise authorized in writing by the Contracting 
Officer, the Contractor will obtain patent agreements to effectuate the 
provisions of subparagraph (e)(1) of this clause from all persons who 
perform any part of the work under this contract, except nontechnical 
personnel, such as clerical employees and manual laborers.
    (k) Background Patents. (1) Background Patent means a domestic 
patent covering an invention or discovery which is not a subject 
invention and which is owned or controlled by the Contractor at any time 
through the completion of this contract:
    (i) Which the contractor, but not the Government, has the right to 
license to others without obligation to pay royalties thereon, and
    (ii) Infringement of which cannot reasonably be avoided upon the 
practice of any specific process, method, machine, manufacture, or 
composition of matter (including relatively minor modifications thereof) 
which is a subject of the research, development, or demonstration work 
performed under this contract.
    (2) The Contractor agrees to and does hereby grant to the Government 
a royalty-free, nonexclusive license under any background patent for 
purposes of practicing a subject of this contract by or for the 
Government in research, development, and demonstration work only.
    (3) The Contractor also agrees that upon written application by DOE, 
it will grant to responsible parties, for purposes of practicing a 
subject of this contract, nonexclusive licenses under any background 
patent on terms that are reasonable under the circumstances. If, 
however, the Contractor believes that exclusive rights are necessary to 
achieve expeditious commercial development or utilization, then a 
request may be made to DOE for DOE approval of such licensing by the 
Contractor.
    (4) Notwithstanding subparagraph (k)(3) of this clause, the 
contractor shall not be obligated to license any background patent if 
the Contractor demonstrates to the satisfaction of the Secretary of 
Energy or designee that:
    (i) A competitive alternative to the subject matter covered by said 
background patent is commercially available or readily introducible from 
one or more other sources; or
    (ii) The Contractor or its licensees are supplying the subject 
matter covered by said background patent in sufficient quantity and at 
reasonable prices to satisfy market needs, or have taken effective steps 
or within a reasonable time are expected to take effective steps to so 
supply the subject matter.
    (l) Publication. It is recognized that during the course of the work 
under this contract, the Contractor or its employees may from time to 
time desire to release or publish information regarding scientific or 
technical developments conceived or first actually reduced to practice 
in the course of or under this contract. In order that public disclosure 
of such information will not adversely affect the patent interests of 
DOE or the Contractor, patent approval for release of publication shall 
be secured from Patent Counsel prior to any such release or publication.
    (m) Forfeiture of rights in unreported subject inventions. (1) The 
Contractor shall forfeit and assign to the Government, at the request of 
the Secretary of Energy or designee, all rights in any subject invention 
which the Contractor fails to report to Patent Counsel within six months 
after the time the Contractor:
    (i) Files or causes to be filed a United States or foreign patent 
application thereon; or
    (ii) Submits the final report required by subparagraph (e)(2)(ii) of 
this clause, whichever is later.
    (2) However, the Contractor shall not forfeit rights in a subject 
invention if, within the time specified in subparagraph (m)(1) of this 
clause, the Contractor:
    (i) Prepares a written decision based upon a review of the record 
that the invention was neither conceived nor first actually reduced to 
practice in the course of or under the contract and delivers the 
decision to Patent Counsel, with a copy to the Contracting Officer; or
    (ii) Contending that the invention is not a subject invention, the 
Contractor nevertheless discloses the invention and all facts pertinent 
to this contention to the Patent Counsel, with a copy to the Contracting 
Officer; or
    (iii) Establishes that the failure to disclose did not result from 
the Contractor's fault or negligence.
    (3) Pending written assignment of the patent application and patents 
on a subject invention determined by the Secretary of Energy or designee 
to be forfeited (such determination to be a final decision under the 
Disputes clause of this contract), the Contractor shall be deemed to 
hold the invention

[[Page 384]]

and the patent applications and patents pertaining thereto in trust for 
the Government. The forfeiture provision of this paragraph (m) shall be 
in addition to and shall not supersede other rights and remedies which 
the Government may have with respect to subject inventions.

                             (End of clause)

[60 FR 11819, Mar. 2, 1995, as amended at 62 FR 42075, Aug. 5, 1997]



952.227-70--952.227-72  [Reserved]



952.227-73  Additional technical data requirements.

    The following clause shall be used in contracts for research, 
development, or demonstration work and in other contracts as directed in 
927.402-3(b).

            Additional Technical Data Requirements (Apr 1984)

    (a) In addition to the technical data specified elsewhere in this 
contract to be delivered, the contracting officer may at any time during 
the contract performance or within one year after final payment call for 
the contractor to deliver any technical data first produced or 
specifically used in the performance of this contract, except technical 
data pertaining to items of standard commercial design.
    (b) The provisions of the Rights in Technical Data clause included 
in this contract are applicable to all technical data called for under 
this Additional Technical Data Requirements clause. Accordingly, nothing 
contained in this clause shall require the contractor to actually 
deliver any technical data, the delivery of which is excused by 
paragraph (e) of the Rights in Technical Data clause.
    (c) When technical data are to be delivered under this clause, the 
contractor will be compensated for appropriate costs for converting such 
data into the prescribed form for reproduction, and for delivery.
[49 FR 12042, Mar 28, 1984; 49 FR 38952, Oct. 2, 1984]



952.227-74  [Reserved]



952.227-75  Rights in technical data--long form.

    As directed by 927.402-3(e), the following clause shall be used in 
all contracts having as a purpose the conduct of research, development, 
or demonstration, or in contracts for supplies, or in any other contract 
where technical data are specified to be delivered in the contract, or 
where the contract contains the Additional Technical Data Requirements 
clause at 952.227-73.

             Rights in Technical Data--Long Form (Apr 1994)

    (a) Definitions.
    (1) Technical data means recorded information regardless of form or 
characteristic, of a scientific or technical nature. It may, for 
example, document research, experimental, developmental, or 
demonstration, or engineering work, or be usable or used to define a 
design or process, or to procure, produce, support, maintain, or operate 
material. The data may be graphic or pictorial delineations in media 
such as drawings or photographs, text in specifications or related 
performance or design type documents or computer software (including 
computer programs, computer software data bases, and computer software 
documentation). Examples of technical data include research and 
engineering data, engineering drawings and associated lists, 
specifications, standards, process sheets, manuals, technical reports, 
catalog item identification, and related information. Technical data as 
used herein do not include financial reports, cost analyses, and other 
information incidental to contract administration.
    (2) Proprietary data means technical data which embody trade secrets 
developed at private expense, such as design procedures or techniques, 
chemical composition of materials, or manufacturing methods, processes, 
or treatments, including minor modifications thereof, provided that such 
data:
    (i) Are not generally known or available from other sources without 
obligation concerning their confidentiality;
    (ii) Have not been made available by the owner to others without 
obligation concerning its confidentiality; and
    (iii) Are not already available to the Government without obligation 
concerning the confidentiality.
    (3) Contract data means technical data first produced in the 
performance of the contract in technical data which are specified to be 
delivered under the contract; technical data that may be called for 
under the Additional Technical Data Requirements clause of the contract, 
if any, or technical data actually delivered in connection with the 
contract.
    (4) Unlimited rights means rights to use, duplicate, or disclose 
technical data, in whole or in part, in any manner and for any purpose 
whatsoever, and to permit others to do so.
    (b) Allocation of rights. (1) The Government shall have:
    (i) Unlimited rights in contract data except as otherwise provided 
below with respect to proprietary data;
    (ii) The right to remove, cancel, correct or ignore any marking not 
authorized by the

[[Page 385]]

terms of this contract on any technical data furnished hereunder, if in 
response to a written inquiry by DOE concerning the propriety of the 
markings, the contractor fails to respond thereto within 60 days or 
fails to substantiate the propriety of the markings. In either case, DOE 
will notify the contractor of the action taken;
    (iii) No rights under this contract in any technical data which are 
not contract data.
    (2) The contractor shall have:
    (i) The right to withhold proprietary data in accordance with the 
provisions of this clause; and
    (ii) The right to use for its private purposes, subject to patent, 
security or other provisions of this contract data it first produces in 
the performance of this contract, provided the data requirements of this 
contract have been met as of the date of the private use of such data. 
The contractor agrees that to the extent it receives or is given access 
to proprietary data or other technical, business or financial data in 
the form of recorded information from DOE or a DOE contractor or 
subcontractor, the contractor shall treat such data in accordance with 
any restrictive legend contained thereon, unless other use is 
specifically authorized by prior written approval of the contracting 
officer.
    (3) Nothing contained in this Rights of Technical Data clause shall 
imply a license to the Government under any patent or be construed as 
affecting the scope of any licenses or other rights otherwise granted to 
the Government under any patent.
    (c) Copyrighted material. (1) The contractor shall not, without 
prior written authorization of the Patent Counsel, establish a claim to 
statutory copyright in any contract data first produced in the 
performance of the contract. To the extent such authorization is 
granted, the Government reserves for itself and others acting on its 
behalf a royalty-free, nonexclusive, irrevocable, worldwide license for 
Governmental purposes to publish, distribute, translate, duplicate 
exhibit and perform any such data copyrighted by the contractor.
    (2) The contractor agrees not to include in the technical data 
delivered under the contract any material copyrighted by the contractor 
and not to knowingly include any material copyrighted by others, without 
first granting or obtaining at no cost a license therein for the benefit 
of the Government of the same scope as set forth in paragraph (c)(1) of 
this section. If such royalty-free license is unavailable and the 
contractor nevertheless determines that such copyrighted material must 
be included in the technical data to be delivered, rather than merely 
incorporated therein by reference, the contractor shall obtain the 
written authorization of the contracting officer to include such 
copyrighted material in the technical data prior to its delivery.
    (d) Subcontracting. It is the responsibility of the contractor to 
obtain from its subcontractors technical data and rights therein, on 
behalf of the Government, necessary to fulfill the contractor's 
obligations to the Government with respect to such data. In the event of 
refusal by a subcontractor to accept a clause affording the Government 
such rights, the contractor shall:
    (1) Promptly submit written notice to the contracting officer 
setting forth reasons for the subcontractor refusal and other pertinent 
information which may expedite disposition of the matter; and
    (2) Not proceed with the subcontract without the written 
authorization of the contracting officer.
    (e) Withholding of proprietary data. Notwithstanding the inclusion 
of the Additional Technical Data Requirements clause in this contract or 
any provision of this contract specifying the delivery of technical 
data, the contractor may withhold proprietary data from delivery, 
provided that the contractor furnishes in lieu of any such proprietary 
data so withheld technical data disclosing the source, size, 
configuration, mating and attachment characteristics, functional 
characteristics, and performance requirements (``Form, Fit and 
Function'' data, e.g., specification control drawing, catalog sheets, 
envelope drawings, etc.), or a general description of such proprietary 
data where ``Form, Fit and Function'' data are not applicable. The 
Government shall acquire no rights to any proprietary data so withheld 
except that such data shall be subject to the ``inspection rights'' 
provisions of paragraph (f), and, if included, the ``Limited rights in 
proprietary data'' provisions of paragraph (g) and the ``Contractor 
licensing'' provisions of paragraph (h).
    (f) Inspection rights. Except as may be otherwise specified in this 
contract for specific items of proprietary data which are not subject to 
this paragraph, the contracting officer's representatives, at all 
reasonable times up to three years after final payment under this 
contract, may inspect at the contractor's facility any proprietary data 
withheld under paragraph (e) and not furnish under paragraph (g), if 
this contract includes such paragraph, for the purposes of verifying 
that such data properly fell within the withholding provision of 
paragraph (e), or for evaluating work performance.

     Alternate I: Additional paragraph (g), limited rights. The 
following paragraph (g) shall be added to the basic clause at 952.227-75 
of this section when it is determined in accordance with 927.402-3(e)(2) 
that delivery of proprietary data is necessary with limited rights in 
the Government.


[[Page 386]]


    (g) Limited rights in proprietary data. Except as may be otherwise 
specified in this contract as technical data which are not subject to 
this paragraph, the contractor shall, upon written request from the 
contracting officer at any time prior to three years after final payment 
under this contract, promptly deliver to the Government any 
``proprietary data'' withheld pursuant to paragraph (e) of the Rights in 
Technical Data clause of this contract. The following legend and no 
other is authorized to be affixed on any ``proprietary data'' delivered 
pursuant to this provision, provided the ``proprietary data'' meets the 
conditions for initial withholding under paragraph (e) of the Rights in 
Technical Data clause. The Government will thereafter treat the 
``proprietary data'' in accordance with such legend.

                    Limited Rights Legend (Apr 1984)

    This technical data contains ``proprietary data,'' furnished under 
``Contract No. ________'' with the U.S. Department of Energy (and 
Purchase Order No. ________ if applicable) which may be duplicated and 
used by the Government with the express limitations that the 
``proprietary data'' may not be disclosed outside the Government or be 
used for purposes of manufacture without prior permission of the 
contractor, except that further disclosure or use may be made solely for 
the following purposes:
    (a) This ``proprietary data'' may be disclosed for evaluation 
purposes under the restriction that the ``proprietary data'' be retained 
in confidence and not further disclosed;
    (b) This ``proprietary data'' may be disclosed to other contractors 
participating in the Government's program of which this contract is 
part, for information or use in connection with the work performed under 
their contracts and under the restriction that the ``proprietary data'' 
be retained in confidence and not be further disclosed; or
    (c) This ``proprietary data'' may be used by the Government or 
others on its behalf for emergency repair or overhaul work under the 
restriction that the ``proprietary data'' be retained in confidence and 
not be further disclosed.
    This legend shall be marked on any reproduction of this data in 
whole or in part.

    Alternate II: Additional paragraph (h), contractor licensing. The 
following paragraph (h) shall be added to the basic clause at 952.227-75 
above when it is determined in accordance with 927.402-3(e)(3) that the 
Government should obtain on behalf of third parties and itself limited 
license rights in and to proprietary contract data.

    (h) Contract licensing. Except as may be otherwise specified in this 
contract as technical data not subject to this paragraph, the contractor 
agrees that upon written application by DOE, it will grant to the 
Government and responsible third parties, for purpose of practicing a 
subject of this contract, a nonexclusive license in any contract data 
which are proprietary data, on terms and conditions reasonable under the 
circumstances including appropriate provisions for confidentiality; 
provided, however, the contractor shall not be obligated to license any 
such data if the contractor demonstrates to the satisfaction of the Head 
of the Agency or designee that:
    (1) Such data are not essential to the manufacture or practice of 
hardware designed or fabricated, or processes developed, under this 
contract;
    (2) Such data, in the form of results obtained by their use, have a 
commercially competitive alternative available or readily introducible 
from one or more other sources;
    (3) Such data, in the form of results obtained by their use, are 
being supplied by the contractor or its licensees in sufficient quantity 
and at reasonable prices to satisfy market needs, or the contractor or 
its licensees have taken effective steps or within a reasonable time are 
expected to take effective steps to so supply such data in the form of 
results obtained by their use; or
    (4) Such data, in the form of results obtained by their use, can be 
furnished by another firm skilled in the art of manufacturing items or 
performing processes of the same general type and character necessary to 
achieve the contract results.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.227-76  Rights in data--special works.

    The following clause shall be included in contracts having as a 
principal purpose or task the production of copyrightable works as 
discussed in 927.402-3(f).

                Rights in Data--Special Works (Apr 1994)

    (a) The term Data as used herein means recorded information 
regardless of form or characteristic, such as writings, sound 
recordings, pictorial reproductions, drawings, or other graphic 
representations, and works of similar nature (whether or not 
copyrighted) which are specified to be delivered under this contract. 
The term includes data such as management studies and data produced 
under support services contracts but does not include financial reports, 
cost analyses, and other information incidental to contract 
administration.

[[Page 387]]

    (b) All data first produced or composed in the course of or under 
this contract shall be the sole property of the Government. Except with 
the prior written permission of the contracting officer, the contractor 
agrees not to assert any rights at common law or in equity or establish 
any claim to statutory copyright in such data. The contractor shall not 
publish or reproduce such data in whole or in part or in any manner of 
form, or authorize others so to do, without the written consent of the 
contracting officer or until such time as the Government may have 
released such data to the public.
    (c) The contractor hereby grants to or will obtain for the 
Government a royalty-free, nonexclusive and irrevocable license 
throughout the world (1) to publish, translate, reproduce, deliver, 
perform, use, and dispose of, in any manner, any and all data which are 
not first produced or composed in the performance of this contract but 
which are incorporated in the work furnished under this contract; and 
(2) to authorize others so to do.
    (d) The contractor shall indemnify and save and hold harmless the 
Government, its officers, agents, and employees acting within the scope 
of their official duties against any liability, including costs and 
expenses, (1) for violation of proprietary rights, copyrights, or rights 
of privacy, arising out of the publication, translation, reproduction, 
delivery, performance, use, or disposition of any data furnished under 
this contract; or (2) based upon any libelous, defamatory, or other 
unlawful matter contained in such data.
    (e) Nothing contained in this clause shall imply a license to the 
Government under any patent, or be construed as affecting the scope of 
any licenses or other rights otherwise granted to the Government under 
any patent.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.227-77  Rights in technical data clause--short form.

    As discussed in 927.402-3(g), the following clause may be used in 
contracts for basic research with educational institutions and in 
contracts with consultants and in other contracts of a similar nature. 
The clause shall not be used in any contract where proprietary 
information of the contractor may be utilized in performance of work 
under the contract.

             Rights in Technical Data--Short Form (Apr 1994)

    (a) Definitions. The definitions of terms set forth in DEAR 927.401 
apply to the extent these terms are used herein.
    (b) Allocation of rights. (1) The Government shall have:
    (i) Unlimited rights in technical data first produced or 
specifically used in the performance of this contract;
    (ii) The right of the contracting officer or his representative to 
inspect at all reasonable times up to three years after final payment 
under this contract all technical data first produced or specifically 
used in the contract (for which inspection the contractor or its 
subcontractor shall afford proper facilities to DOE); and
    (iii) The right to have any technical data first produced or 
specifically used in the performance of this contract delivered to the 
Government as the contracting officer may from time to time direct 
during the progress of the work, or in any event as the contracting 
officer shall direct upon completion or termination of this contract.
    (2) The contractor shall have:
    The right to use for its private purposes, subject to patent, 
security or other provisions of this contract, technical data it first 
produces in the performance of this contract provided the data 
requirements of this contract have been met as of the date of the 
private use of such data. The contractor agrees that to the extent it 
receives or is given access to proprietary data or other technical, 
business or financial data in the form of recorded information from DOE 
or a DOE contractor or subcontractor, the contractor shall treat such 
data in accordance with any restrictive legend contained thereon, unless 
other use is specifically authorized by prior written approval of the 
contracting officer.
    (c) Copyrighted material. (1) The contractor agrees to, and does 
hereby grant to the Government, and to its officers, agents, servants 
and employees acting within the scope of their duties:
    (i) A royalty-free, nonexclusive, irrevocable license to reproduce, 
translate, publish, use, and dispose of and to authorize others to do 
so, all copyrightable material first produced or composed in the 
performance of this contract by the contractor, its employees or any 
individual or concern specifically employed or assigned to originate and 
prepare such material; and
    (ii) A license as aforesaid under any and all copyrighted or 
copyrightable works not first produced or composed by the contractor in 
the performance of this contract but which are incorporated in the 
material furnished

[[Page 388]]

under the contract, provided that such license shall be only to the 
extent the contractor now has, or prior to completion or final 
settlement of the contract may acquire, the right to grant such license 
without becoming liable to pay compensation to others solely because of 
such grant.
    (2) The contractor agrees that it will not knowingly include any 
material copyrighted by others in any written or copyrightable material 
furnished or delivered under this contract without a license as provided 
for in paragraph (c)(1)(ii) hereof, or without the consent of the 
copyright owner, unless it obtains specific written approval of the 
contracting officer for the inclusion of such copyrighted material.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.227-78  Rights in technical data--facility.

    As discussed in 970.2702 the following clause is to be used in 
contracts for the operation of Government-owned facilities (GOCO's).

              Rights in Technical Data--Facility (Apr 1994)

    (a) Definitions.
    (1) Technical data means recorded information, regardless of form or 
characteristic, of a scientific or technical nature. It may, for 
example, document research, experimental, developmental, or 
demonstration, or engineering work or be usable or used to define a 
design or process or to procure, produce, support, maintain, or operate 
material. The data may be graphic or pictorial delineations in media 
such as drawings or photographs, text in specifications or related 
performance or design type documents, or computer software (including 
computer programs, computer software data bases and computer software 
documentation). Examples of technical data include research and 
engineering data, engineering drawings and associated lists, 
specifications, standards, process sheets, manuals, technical reports, 
catalog item identification, and related information. Technical data as 
used herein does not include financial reports, cost analyses, and other 
information incidental to contract administration.
    (2) Proprietary data means technical data which embody trade secrets 
developed at private expense, such as design procedures or techniques, 
chemical composition of materials, or manufacturing methods, processes, 
or treatments, including minor modifications thereof, provided that such 
data:
    (i) Are not generally known or available from other sources without 
obligation concerning their confidentiality;
    (ii) Have not been made available by the owner to others without 
obligation concerning their confidentiality; and
    (iii) Are not already available to the Government without obligation 
concerning their confidentiality.
    (3) Unlimited rights means rights to use, duplicate, or disclose 
technical data, in whole or in part, in any manner and for any purpose 
whatsoever, and to permit others to do so.
    (b) Allocation of rights. (1) The Government shall have:
    (i) Ownership in all technical data first produced in the 
performance of the contract;
    (ii) The right to inspect technical data first produced or 
specifically used in the performance of the contract at all reasonable 
times (for which inspection the proper facilities shall be afforded DOE 
by the contractor and its subcontractors);
    (iii) The right to have all technical data first produced or 
specifically used in the performance of the contract delivered to the 
Government or otherwise disposed of by the contractor, either as the 
contracting officer may from time to time direct during the progress of 
the work or in any event as the contracting officer shall direct upon 
completion or termination of this contract, provided that nothing 
contained in this paragraph shall require the contractor to actually 
deliver any technical data, the delivery of which is excused by this 
Rights in Technical Data clause;
    (iv) Unlimited rights in technical data specifically used in the 
performance of this contract, except technical data pertaining to items 
of standard commercial design; the contractor agrees to leave a copy of 
such technical data at the facility or plant to which such data relate, 
and to make available for access or to deliver to the Government such 
data upon request by the contracting officer; provided, that if such 
data are proprietary, the rights of the Government in such data shall be 
governed solely by the provisions of paragraph (e), ``Limited Rights in 
Proprietary Data,'' hereof, if a part of this clause.
    (v) The right to remove, cancel, correct, or ignore any marking not 
authorized by the terms of this contract on any technical data furnished 
hereunder if, in response to a written inquiry by DOE concerning the 
propriety of the markings, the contractor fails to respond thereto 
within 60 days or fails to substantiate the propriety of the markings. 
In either case DOE will notify the contractor of the action taken.
    (2) The contractor shall have:
    (i) The right to withhold its proprietary data in accordance with 
the provisions of this clause; and
    (ii) The right to use for its private purposes, subject to patent, 
security or other provisions of this contract, technical data it

[[Page 389]]

first produces in the performance of this contract, provided the data 
requirement of this contract have been met as of the date of the private 
use of such data. The contractor agrees that to the extent it receives 
or is given access to proprietary data or other technical, business or 
financial data in the form of recorded information from DOE or a DOE 
contractor or subcontractor, the contractor shall treat such data in 
accordance with any restrictive legend contained thereon, unless use is 
specifically authorized by prior written approval of the contracting 
officer.
    (3) Nothing contained in this clause shall imply a license to the 
Government under any patent or be construed as affecting the scope of 
any licenses or other rights otherwise granted to the Government under 
any patent.
    (c) Copyrighted material. (1) The contractor shall not, without 
prior written authorization of the Patent Council establish a claim to 
statutory copyright in any technical data first produced in the 
performance of this contract. To the extent such authorization is 
granted, the Government reserves for itself and others acting on its 
behalf, a royalty-free, nonexclusive, irrevocable, world-wide license 
for Governmental purposes to publish, distribute, translate, duplicate, 
exhibit, and perform any such data copyrighted by the contractor.
    (2) The contractor agrees not to include in the technical data 
delivered under the contract any material copyrighted by the contractor 
and not to knowlingly include any material copyrighted by others without 
first granting or obtaining at no cost a license therein for the benefit 
of the Government of the same scope as set forth in paragraph (c)(1) 
above. If the contractor believes that such copyrighted material for 
which the license cannot be obtained must be included in the technical 
data to be delivered, rather than merely incorporated therein by 
reference, the contractor shall obtain the written authorization of the 
contracting officer to include such material in the technical data prior 
to its delivery.
    (d) Subcontracting. (1) Unless otherwise directed by the contracting 
officer, the contractor agrees to use in subcontracts having as a 
purpose the conduct of research, development, and demonstration work or 
in subcontracts for supplies, the contract clause provisions in 48 CFR 
952.227-75 in accordance with the policy and procedures of 48 CFR 
927.402-1, 927.402-2 and 927.402-3.
    (2) It is the responsibility of the contractor to obtain from its 
subcontractors technical data and rights therein, on behalf of the 
Government, necessary to fulfill the contractor's obligations to the 
Government with respect to such data. In the event of refusal by a 
subcontractor to accept a clause affording the Government such rights, 
the contractor shall:
    (i) Promptly submit written notice to the contracting officer 
setting forth reasons for the subcontractor's refusal and other 
pertinent information which may expedite disposition of the matter; and
    (ii) Not proceed with the subcontract without the written 
authorization of the contracting officer.
[49 FR 12042, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994; 62 
FR 2312, Jan. 16, 1997]



952.227-79  Limited rights in proprietary data.

    As discussed in 970.2702(c) the following paragraph may be used as a 
supplement to the clause at 952.227-78 where it is determined that 
delivery of proprietary data is necessary with limited rights in the 
Government.

    (e) Except as may be otherwise specified in this contract as 
technical data which are not subject to this paragraph, the contractor 
agrees to and does hereby grant to the Government an irrevocable, 
nonexclusive paid-up license and right to use by or for the Government, 
any proprietary data of the contractor specifically used in the 
performance of this contract; provided, however, that to the extent that 
any proprietary data when furnished or delivered is specifically 
indentified by the contractor at the time of initial delivery to the 
Government or a representative of the Government, such data shall not be 
used within or outside the Government, except as provided in the 
``Limited Rights Legend'' set forth below. All such proprietary data 
shall be marked with the following ``Limited Rights Legend'':

                     Limits Rights Legend (Apr 1994)

    This Technical data contains ``proprietary data,'' furnished under 
contract No. ______ with the U.S. Department of Energy (and purchase 
order No. ______ if applicable) which may be duplicated and used by the 
Government with the express limitations that the ``proprietary data'' 
may not be disclosed outside of the Government or be used for purposes 
of manufacture without prior permission of the following purposes:
    (a) This `` proprietary data'' may be disclosed for evaluation 
purposes under the restriction that the ``proprietary data'' be retained 
in confidence and not be further disclosed;
    (b) This ``proprietary data'' may be disclosed to other contractors 
participating in the Government's program of which this contract is a 
part for information or use in connection with the work performed under 
their contracts and under the restriction that the

[[Page 390]]

``proprietary data'' be retained in confidence and not be further 
disclosed; or
    (c) This ``proprietary data'' may be used by the Government or 
others on its behalf for emergency repair or overhaul work under the 
restriction that the ``proprietary data'' be retained in confidence and 
not be further disclosed.
    This legend shall be marked on any reproduction of this data in 
whole or in part.
[49 FR 12042, Mar. 28, 1984, as amended at 56 FR 41965, Aug. 26, 1991; 
59 FR 9109, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.227-82  Rights to proposal data.

    Pursuant to 927.7002(d), include this clause in any contract which 
the decision to make the award included consideration of a technical 
proposal.

                   Rights to Proposal Data (Apr 1994)

    Except for technical data contained on pages ____ of the 
contractor's proposal dated ____ which are asserted by the contractor as 
being proprietary data, it is agreed that, as a condition of the award 
of this contract, and notwithstanding the provisions of any notice 
appearing on the proposal, the Government shall have the right to use, 
duplicate, disclose and have others do so for any purpose whatsoever, 
the technical data contained in the proposal upon which this contract is 
based.
[49 FR 12042, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994; 62 
FR 2312, Jan. 16, 1997]



952.227-83  Rights in technical data solicitation representation.

    Pursuant to 48 CFR 927.7004-1 and 927.7004-2, include this provision 
and the legend at FAR 52.215-12 in solicitations which may result in 
contracts for reserach, development, or demonstration work or contracts 
for supplies in which delivery of required technical data is 
contemplated.

      Rights in Technical Data Solicitation Instruction (Apr 1984)

    The section of this solicitation which describes the work to be 
performed also sets forth DOE's know requirements for technical data. 
The Additional Technical Data Requirements clause, if included in this 
solicitation, provides the Government with the option to order 
additional technical data, the requirements for which are not known at 
the time of contracting. There is, however, a built-in limitation on the 
kind of technical data which may be required. This limitation provides 
that the contractor may withhold delivery of proprietary data. 
Accordingly, it is necessary that your proposal state that the work to 
be performed and the known requirements for technical data as set forth 
in the solicitation have been reviewed, and either state that, to the 
best of your knowledge, not data will be withheld, or submit a list 
identifying the proprietary data which, to the best of your knowledge, 
will likely be used in the contract performance and will be withheld.
[49 FR 12042, Mar. 28, 1984, as amended at 62 FR 42075, Aug. 5, 1997]



952.227-84  Notice of right to request patent waiver.

    Pursuant to 927.7005, include this provision in all solicitations 
which may result in contracts calling for research, development, or 
demonstration work.

                Right To Request Patent Waiver (Apr 1984)

    Offerors and prospective contractors, in accordance with applicable 
statutes and the Department of Energy Acquisition Regulation, have the 
right to request, in advance of or within 30 days after the effective 
data of contracting, a waiver of all or any part of the rights of the 
United States in subject inventions. Small business firms and domestic 
nonprofit organizations normally will receive the Patent Rights clause 
of 952.227-71 which permits the contractor to retain title to subject 
inventions, except in contracts for management or operation of a 
Government-owned research or production facility and in contracts 
involving exceptional circumstances or intelligence activities. 
Therefore small business firms and nonprofit organizations normally need 
not request a waiver.



952.231-70  Date of incurrence of cost.

    In accordance with 931.205-32, insert the following clause when 
advance understandings have been negotiated regarding costs incurred 
prior to the contract effective date:

                  Date of Incurrence of Cost (Apr 1984)

    The Contractor shall be entitled to reimbursement for costs incurred 
in an amount not to exceed $ ____ on or after ____ which, if incurred 
after this contract has been entered into, would have been reimbursable 
under the provisions of this contract.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984]



952.233-2  Service of protest.

    As prescribed in 48 CFR 933.106(a), add the following to the end of 
the clause at FAR 52.233-2:


[[Page 391]]


    (c) Another copy of a protest filed with the General Accounting 
Office shall be furnished to the following address within the time 
periods described in paragraph (b) of this clause: U.S. Department of 
Energy, Assistant General Counsel for Procurement and Financial 
Assistance (GC-61), 1000 Independence Avenue, S.W., Washington, DC 
20585, Fax: (202) 586-4546.
[61 FR 41711, Aug. 9, 1996]



952.233-4  Notice of protest file availability.

    As prescribed in 933.106(b), insert the following provision:

             Notice of Protest File Availability (Sep 1996)

    (a) If a protest of this procurement is filed with the General 
Accounting Office (GAO) in accordance with 4 CFR part 21, any actual or 
prospective offeror may request the Department of Energy to provide it 
with reasonable access to the protest file pursuant to FAR 
33.104(a)(3)(ii), implementing section 1065 of Public Law 103-355. Such 
request must be in writing and addressed to the contracting officer for 
this procurement.
    (b) Any offeror who submits information or documents to the 
Department for the purpose of competing in this procurement is hereby 
notified that information or documents it submits may be included in the 
protest file that will be available to actual or prospective offerors in 
accordance with the requirements of FAR 33.104(a)(3)(ii). The Department 
will be required to make such documents available unless they are exempt 
from disclosure pursuant to the Freedom of Information Act. Therefore, 
offerors should mark any documents as to which they would assert that an 
exemption applies. (See 10 CFR part 1004.)
[61 FR 41711, Aug. 9, 1996]



952.233-5  Agency protest review.

    As prescribed in 48 CFR 933.106(c), insert the following provision:

                    Agency Protest Review (Sep 1996)

    Protests to the Agency will be decided either at the level of the 
Head of the Contracting Activity or at the Headquarters level. The 
Department of Energy's agency protest procedures, set forth in 933.103, 
elaborate on these options and on the availability of a suspension of a 
procurement that is protested to the agency. The Department encourages 
potential protesters to discuss their concerns with the contracting 
officer prior to filing a protest.
[61 FR 41711, Aug. 9, 1996]



952.235-70  Key personnel.

    In accordance with 935.070, insert the following clause.

                        Key Personnel (Apr 1994)

    The personnel specified in an attachment to this contract are 
considered to be essential to the work being performed hereunder. Prior 
to diverting any of the specified individuals to other programs, the 
Contractor shall notify the contracting officer reasonably in advance 
and shall submit justification (including proposed substitutions) in 
sufficient detail to permit evaluation of the impact on the program. No 
diversion shall be made by the contractor without the written consent of 
the contracting officer: Provided, that the contracting officer may 
ratify in writing such diversion and such ratification shall constitute 
the consent of the contracting officer required by this clause. The 
attachment to this contract may be amended from time to time during the 
course of the contract to either add or delete personnel, as 
appropriate.
[49 FR 12042, Mar. 28, 1984, as amended at 56 FR 41965, Aug. 26, 1991; 
59 FR 9109, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.236  Construction and architect-engineer contracts.



952.236-70  Administrative terms for architect-engineer contracts.

    As prescribed at 936.702(a) the following additional terms shall be 
included in Standard Form 252, Item 6:

    (a) Description of project. The contracting officer shall include. 
(As full a description as is feasible should be inserted. If the 
architect-engineer services are to be furnished for a construction 
project, describe the facilities involved, including any auxiliary 
facilities that may be required.)
    (b) Statement of architect-engineer services. The contractor shall, 
within the time specified in the contract, or if not specified therein, 
in the shortest reasonable time, furnish for the construction project 
the architect-engineer services described below, subject to such further 
detailed requirements as may be appended to this contract by agreement 
of the parties.

    Note A: This form of contract provides for completion of the 
architect-engineer services ``within the shortest reasonable time.'' The 
form may be modified to provide for completion of separable parts of the 
work at different times.
    Note B: When title I, II, or III services are to be furnished, the 
following language may be used to describe such services. Modifications 
in the text of the language may be

[[Page 392]]

made to omit inappropriate items or, where necessary, to meet particular 
circumstances.

                      Title I--Preliminary Services

    (1) Conduct or arrange for, by subcontract or otherwise as approved 
by the contracting officer, and supervise all necessary topographical 
and other field surveys, the preparation of maps, and necessary test 
boring and other surface investigations.
    (2) Consult and collaborate with DOE to determine the requirements 
which will govern the design of the project and to establish 
architectural and engineering criteria for such design.
    (3) Conduct preliminary studies, and prepare preliminary sketches, 
drawings, layout plans, outline specifications, and reports showing 
features and characteristics of the design proposed to meet DOE's 
requirements. If more than three studies, including sketches, drawings, 
plans, outline specifications, or documents are required because of 
changes initiated by DOE, an equitable adjustment in the lump-sum 
compensation will be made in accordance with provisions of the Changes 
clause.
    (4) The drawings, plans, and outline specifications and documents 
shall be prepared in such form and furnished in such quantity as 
directed by DOE.

    Note: Specific quantities of the drawings, plans, outline 
specifications, and documents should be indicated here or elsewhere in 
the contract.

    (5) Prepare preliminary estimates of cost and time schedule for (i) 
completion of the design, working drawings, and specifications, and (ii) 
construction.
    (6) Prepare preliminary estimates of material quantities required 
for construction.

                        Title II--Design Services

    (1) Upon approval by DOE of preliminary plans and estimates, 
undertake the design of the construction project.
    (2) Undertake restudy and redesign work due to minor deviations from 
the approved preliminary work as may be required by DOE.
    (3) Prepare and revise, for the approval of DOE, and furnish 
complete sets of contract bidding documents, including working drawings, 
details, and specifications for construction, in such form and quantity 
and including such provisions as may be required by law or the 
directions of DOE.

    Note: Specific quantities of drawings and specifications should be 
indicated here or elsewhere in the contract.

    (4) Prepare, or when directed by DOE, participate with others in the 
preparation of a detailed estimate of the cost of construction based on 
the approved design and working drawings and specifications.
    (5) Assist DOE in securing, analyzing, and evaluating construction 
bids or proposals.
    (6) When requested, consult with and advise DOE on any questions 
which may arise in connection with the architect-engineer services 
described in this contract.

                 Title III--Supervision of Construction

    (1) Furnish and maintain governing lines and benchmarks to provide 
horizontal and vertical controls to which construction progress may be 
referred.
    (2) Check and approve or require revision of, all vendors' shop 
drawings to assure conformity with the approved design and working 
drawings and specifications.
    (3) Inspect the execution of construction so as to assure adherence 
to approved working drawings and specifications.
    (4) Inspect construction workmanship and materials, and equipment, 
and report to DOE as to their conformity or nonconformity to the 
approved working drawings and specifications.
    (5) Make or acquire such field or laboratory tests of construction 
workmanship, materials, and equipment, as DOE may require or approve.
    (6) Prepare estimates of reasonable amounts of increase or decrease 
in contract price and/or contract completion time for contract 
modification, evaluate proposal submitted by the constructor for such 
contract adjustment and make recommendations to the contracting officer 
for use in negotiating.
    (7) Prepare reports and make recommendations on status of deliveries 
or materials and equipment as DOE may require or approve.
    (8) Prepare monthly and other reports of the progress of 
construction, as may be required, and partial, interim, and final 
estimates and reports of quantities and values of construction work 
performed, for payment or other purposes.
    (9) Furnish ______ set(s) of reproducible ``as-built'' record 
drawings of the type specified by DOE and ______ set(s) of marked-up 
specifications, showing construction as actually accomplished.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994]



952.236-71  Inspection in architect-engineer contracts.

    As prescribed at 936.609-3 insert the following clause.

                          Inspection (Apr 1994)

    The Government, through any authorized representatives, has the 
right at all reasonable times, to inspect, or otherwise evaluate

[[Page 393]]

the work performed or being performed hereunder and the premises in 
which it is being performed. If any inspection, or evaluation is made by 
the Government on the premises of the Contractor or a subcontractor, the 
Contractor shall provide and shall require his subcontractors to provide 
all reasonable facilities and assistance for the safety and convenience 
of the Government representatives in the performance of their duties. 
All inspections and evaluations shall be performed in such a manner as 
will not unduly delay the work.
[49 FR 12042, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994; 62 
FR 2312, Jan. 16, 1997]



952.236-72  Nonrefundable fee for plans and specifications.

    In accordance with the requirement at 936.202(j) include the 
following in solicitations for construction.

        Nonrefundable Fee for Plans and Specifications (Apr 1984)

    A fee of $______ is required for the plans and specifications 
referenced in this solicitation. Send check or money order to 
__________. The fee is not refundable. Plans and specifications need not 
be returned.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994]



952.237-70  Collective bargaining agreements--protective services.

    As prescribed in 937.7040, insert the following clause:

    Collective Bargaining Agreements--Protective Services (Aug 1993)

    When negotiating collective bargaining agreements applicable to the 
work force under this contract, the Contractor shall use its best 
efforts to ensure such agreements contain provisions designed to assure 
continuity of services. All such agreements entered into during the 
contract period of performance should provide that grievances and 
disputes involving the interpretation or application of the agreement 
will be settled without resorting to strike, lockout, or other 
interruption of normal operations.
    For this purpose, each collective bargaining agreement should 
provide an effective grievance procedure with arbitration as its final 
step, unless the parties mutually agree upon some other method of 
assuring continuity of operations. As part of such agreements, 
management and labor should agree to cooperate fully with the Federal 
Mediation and Conciliation Service. The contractor shall include the 
substance of this clause in any subcontracts for protective services.
[58 FR 36152, July 6, 1993; 58 FR 43287, Aug. 16, 1993]



952.245  Clauses related to government property.



952.245-2  Government property (fixed-price contracts).

    Modify FAR 52.245-2 by adding ``and the DOE Acquisition Regulation 
Subpart 945.5,'' after the reference to FAR Subpart 45.5 in the first 
sentence of paragraphs (e)(1) and (e)(2) of the clause.



952.245-5  Government property (cost reimbursement, time-and-materials, or labor-hour contracts.)

    Modify FAR 52.245-5 by adding ``and DOE Acquisition Regulation 
Subpart 945.5'' after the reference to FAR Subpart 45.5 in paragraphs 
(e)(1) and (e)(2) of the clause.



952.247-70  Foreign travel.

    When foreign travel may be required under the contract insert the 
following clause.

                        Foreign Travel (FEB 1997)

    (a) Foreign travel, when charged directly, shall be subject to the 
prior approval of the contracting officer for each separate trip 
regardless of whether funds for such travel are contained in an approved 
budget. Foreign travel is defined as any travel outside of Canada, 
Mexico and the United States and its territories and possessions.
    (b) Request for approval shall be submitted at least 45 days prior 
to the planned departure date, be on a Request for Approval of Foreign 
Travel form, and when applicable, include a notification of proposed 
soviet-bloc travel.
[49 12042, Mar. 28, 184, as amended at 62 FR 2312, Jan. 16, 1997]



952.249  Clauses related to termination.



952.249-70  Termination clause for cost-reimbursement architect-engineer contracts.

    In accordance with the provisions prescribed at 949.505 include the 
following clause in a cost-reimbursement architect-engineer contract.

                         Termination (Apr 1994)

    (a) Notice of termination for default or convenience. The 
contracting officer may at

[[Page 394]]

any time terminate performance of the work under this contract in whole 
or from time to time in part for the default of the architect-engineer 
or for the convenience of the Government by written notice to the 
architect-engineer stating the ground for termination. Such termination 
shall be effective in the manner and upon the date specified in said 
notice and shall be without prejudice to any claims which the Government 
may have against the architect-engineer. Upon receipt of such notice and 
except as otherwise directed by the contracting officer, the architect-
engineer shall:
    (1) Stop work under the contract on the date and to the extent 
specified in the notice of termination;
    (2) Place no further orders or subcontracts for materials, services, 
or facilities, except as may be necessary for completion of such portion 
of the work under the contract as is not terminated; and
    (3) Terminate all orders and subcontracts to the extent they relate 
to the performance of work terminated by the notice of termination.
    (b) Termination for default.
    (1) If the architect-engineer refuses or fails to prosecute the 
work, or any separable part thereof, with such diligence as will ensure 
its completion within the time specified in this contract, or any 
extension thereof; or fails to complete said work within such time; or 
if the architect-engineer fails to perform any of the other requirements 
of this contract, and does not cure such failure within a period of 10 
days (or such longer period as the contracting officer may authorize in 
writing) after receipt of notice from the contracting officer specifying 
such failure, the contracting officer may terminate for default the 
architect-engineer's right to proceed with the work as to which there 
has been delay, provided that the performance of the work shall not be 
terminated for default because of any delays in the completion of work 
due to unforeseeable causes beyond the control and without the fault or 
negligence of the architect-engineer, including, but not restricted to, 
acts of God, or the public enemy, acts of the Government in either its 
sovereign or contractual capacity, acts of another architect-engineer in 
the performance of a contract with the Government, fires, floods, 
epidemics, quarantine restrictions, strikes, freight embargoes, and 
unusually severe weather or delay of subcontractors or suppliers arising 
from unforeseeable causes beyond the control and without the fault or 
negligence of both the architect-engineer and subarchitect-engineers or 
suppliers; and if the architect-engineer within ten (10) days from the 
beginning of any such delay (unless the contracting officer grants a 
further period of time prior to the date of final settlement of the 
contract) notifies the contracting officer in writing of the causes of 
delay. The contracting officer shall ascertain the facts and the extent 
of the delay and extend the time for completing the work when, in his 
judgment, the findings of fact justify such an extension, and his 
findings of fact thereon shall be final and conclusive on the parties 
hereto, subject only to appeal by the architect-engineer to the head of 
the agency or his designee in accordance with ``Disputes'' clause of 
this contract.
    (2) If, after notice of termination of this contract for default 
under (1) above, it is determined for any reason that the architect-
engineer was not in default pursuant to (1), or that the architect-
engineer failure to perform or to make progress in performance is due to 
causes beyond the control and without the fault or negligence of the 
architect-engineer pursuant to the provisions of this clause relating to 
excusable delays, the notice of termination shall be deemed to have been 
issued for the convenience of the Government under this clause, and the 
rights and obligations to the parties hereto shall in such event be 
governed accordingly.
    (c) Liability for costs on default. If performance of the work under 
this contract is terminated for the default of the architect-engineer, 
the Government may complete or employ any other person or persons to 
complete the work, and the architect-engineer shall be liable to the 
Government for increased costs occasioned the Government by the default.
    (d) Terms of settlement. Upon the termination of performance of work 
under this contract, full and complete settlement of all claims of the 
architect-engineer with respect to the terminated work shall be made as 
follows:
    (1) Assumption of contractor's obligations. The Government shall 
have the right in its decision to assume all obligations, commitments, 
and claims that the architect-engineer may have theretofore in good 
faith undertaken or incurred in connection with the terminated work, the 
cost of which would be allowable in accordance with the provisions of 
this contract; and the architect-engineer shall, as a condition of 
receiving the payments mentioned in this article, execute and deliver 
all such papers and take all such steps as the contracting officer may 
require for the purpose of fully vesting in the Government all the 
rights and benefits of the architect-engineer, related to such 
obligations, commitments, and claims.
    (2) Payments for allowable costs. The Government shall treat as 
allowable costs all expenditures made in accordance with the clause 
herein entitled ``Allowable cost and Payment,'' not previously so 
allowed or otherwise credited.
    (3) Payment for termination expense. If performance of work under 
the contract is terminated for the convenience of the Government, the 
Government shall reimburse the

[[Page 395]]

architect-engineer for such further expenditures made after the date of 
termination for the protection of Government property and for such legal 
and accounting services in connection with settlement as are required or 
approved by the contracting officer.
    (4) Payments on account of fixed fee. If performance work under the 
contract is terminated for the convenience of the Government, the 
architect-engineer shall be paid that portion of the fixed fee which the 
work actually completed, so determined by the contracting officer, bears 
to the entire work under this contract less payments previously made on 
account of the fee. If performance of the work under the contract is 
terminated for the default of the architect-engineer, no further payment 
beyond that amount due on completed work with appropriate fee payment, 
shall accrue on account of the fixed price.
    (5) Computation of amount due. In arriving at the amount, if any, 
due the architect-engineer under this article, there shall be deducted 
from what would otherwise be due (i) all unliquidated advances and all 
other unliquidated payments on account theretofore made to the 
contractor, (ii) any claims of the Government against the contractor in 
connection with this contract, and (iii) all deductions due under the 
terms of this contract and not otherwise recovered by or credited to the 
Government.
    (6) Property accounting and release. The architect-engineer shall 
furnish the accounting for Government-owned property required by the 
clause entitled ``Property'' and the assignment, closing financial 
statement, and release required by the clause entitled ``Allowable Cost 
and Payments.''
    (e) Rights and remedies of the Government. The rights and remedies 
of the Government provided in this article are in addition to any other 
rights and remedies provided by law or under this contract.
[49 FR 12042, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



952.250  Clauses related to indemnification of contractors.



952.250-70  Nuclear hazards indemnity agreement.

    Insert the following clause in accordance with section 950.7006.

             Nuclear Hazards Indemnity Agreement (JUN 1996).

    (a) Authority. This clause is incorporated into this contract 
pursuant to the authority contained in subsection 170d. of the Atomic 
Energy Act of 1954, as amended (hereinafter called the Act.)
    (b) Definitions. The definitions set out in the Act shall apply to 
this clause.
    (c) Financial protection. Except as hereafter permitted or required 
in writing by DOE, the contractor will not be required to provide or 
maintain, and will not provide or maintain at Government expense, any 
form of financial protection to cover public liability, as described in 
paragraph (d)(2) below. DOE may, however, at any time require in writing 
that the contractor provide and maintain financial protection of such a 
type and in such amount as DOE shall determine to be appropriate to 
cover such public liability, provided that the costs of such financial 
protection are reimbursed to the contractor by DOE.
    (d)(1) Indemnification. To the extent that the contractor and other 
persons indemnified are not compensated by any financial protection 
permitted or required by DOE, DOE will indemnify the contractor and 
other persons indemnified against (i) claims for public liability as 
described in subparagraph (d)(2) of this clause; and (ii) such legal 
costs of the contractor and other persons indemnified as are approved by 
DOE, provided that DOE's liability, including such legal costs, shall 
not exceed the amount set forth in section 170e.(1)(B) of the Act in the 
aggregate for each nuclear incident or precautionary evacuation 
occurring within the United States or $100 million in the aggregate for 
each nuclear incident occurring outside the United States, irrespective 
of the number of persons indemnified in connection with this contract.
    (2) The public liability referred to in subparagraph (d)(1) of this 
clause is public liability as defined in the Act which (i) arises out of 
or in connection with the activities under this contract, including 
transportation; and (ii) arises out of or results from a nuclear 
incident or precautionary evacuation, as those terms are defined in the 
Act.
    (e)(1) Waiver of Defenses. In the event of a nuclear incident, as 
defined in the Act, arising out of nuclear waste activities, as defined 
in the Act, the contractor, on behalf of itself and other persons 
indemnified, agrees to waive any issue or defense as to charitable or 
governmental immunity.
    (2) In the event of an extraordinary nuclear occurrence which:
    (i) Arises out of, results from, or occurs in the course of the 
construction, possession, or operation of a production or utilization 
facility; or
    (ii) Arises out of, results from, or occurs in the course of 
transportation of source material, by-product material, or special 
nuclear material to or from a production or utilization facility; or
    (iii) Arises out of or results from the possession, operation, or 
use by the contractor

[[Page 396]]

or a subcontractor of a device utilizing special nuclear material or by-
product material, during the course of the contract activity; or
    (iv) Arises out of, results from, or occurs in the course of nuclear 
waste activities, the contractor, on behalf of itself and other persons 
indemnified, agrees to waive:
    (A) Any issue or defense as to the conduct of the claimant 
(including the conduct of persons through whom the claimant derives its 
cause of action) or fault of persons indemnified, including, but not 
limited to:
    1. Negligence;
    2. Contributory negligence;
    3. Assumption of risk; or
    4. Unforeseeable intervening causes, whether involving the conduct 
of a third person or an act of God;
    (B) Any issue or defense as to charitable or governmental immunity; 
and
    (C) Any issue or defense based on any statute of limitations, if 
suit is instituted within 3 years from the date on which the claimant 
first knew, or reasonably could have known, of his injury or change and 
the cause thereof. The waiver of any such issue or defense shall be 
effective regardless of whether such issue or defense may otherwise be 
deemed jurisdictional or relating to an element in the cause of action. 
The waiver shall be judicially enforceable in accordance with its terms 
by the claimant against the person indemnified.
    (v) The term extraordinary nuclear occurrence means an event which 
DOE has determined to be an extraordinary nuclear occurrence as defined 
in the Act. A determination of whether or not there has been an 
extraordinary nuclear occurrence will be made in accordance with the 
procedures in 10 CFR part 840.
    (vi) For the purposes of that determination, offsite as that term is 
used in 10 CFR part 840 means away from ``the contract location'' which 
phrase means any DOE facility, installation, or site at which 
contractual activity under this contract is being carried on, and any 
contractor-owned or controlled facility, installation, or site at which 
the contractor is engaged in the performance of contractual activity 
under this contract.
    (3) The waivers set forth above:
    (i) Shall be effective regardless of whether such issue or defense 
may otherwise be deemed jurisdictional or relating to an element in the 
cause of action;
    (ii) Shall be judicially enforceable in accordance with its terms by 
the claimant against the person indemnified;
    (iii) Shall not preclude a defense based upon a failure to take 
reasonable steps to mitigate damages;
    (iv) Shall not apply to injury or damage to a claimant or to a 
claimant's property which is intentionally sustained by the claimant or 
which results from a nuclear incident intentionally and wrongfully 
caused by the claimant;
    (v) Shall not apply to injury to a claimant who is employed at the 
site of and in connection with the activity where the extraordinary 
nuclear occurrence takes place, if benefits therefor are either payable 
or required to be provided under any workmen's compensation or 
occupational disease law;
    (vi) Shall not apply to any claim resulting from a nuclear incident 
occurring outside the United States;
    (vii) Shall be effective only with respect to those obligations set 
forth in this clause and in insurance policies, contracts or other proof 
of financial protection; and
    (viii) Shall not apply to, or prejudice the prosecution or defense 
of, any claim or portion of claim which is not within the protection 
afforded under (A) the limit of liability provisions under subsection 
170e. of the Act, and (B) the terms of this agreement and the terms of 
insurance policies, contracts, or other proof of financial protection.
    (f) Notification and litigation of claims. The contractor shall give 
immediate written notice to DOE of any known action or claim filed or 
made against the contractor or other person indemnified for public 
liability as defined in paragraph (d)(2). Except as otherwise directed 
by DOE, the contractor shall furnish promptly to DOE, copies of all 
pertinent papers received by the contractor or filed with respect to 
such actions or claims. DOE shall have the right to, and may collaborate 
with, the contractor and any other person indemnified in the settlement 
or defense of any action or claim and shall have the right to (1) 
require the prior approval of DOE for the payment of any claim that DOE 
may be required to indemnify hereunder; and (2) appear through the 
Attorney General on behalf of the contractor or other person indemnified 
in any action brought upon any claim that DOE may be required to 
indemnify hereunder, take charge of such action, and settle or defend 
any such action. If the settlement or defense of any such action or 
claim is undertaken by DOE, the contractor or other person indemnified 
shall furnish all reasonable assistance in effecting a settlement or 
asserting a defense.
    (g) Continuity of DOE obligations. The obligations of DOE under this 
clause shall not be affected by any failure on the part of the 
contractor to fulfill its obligation under this contract and shall be 
unaffected by the death, disability, or termination of existence of the 
contractor, or by the completion, termination or expiration of this 
contract.
    (h) Effect of other clauses. The provisions of this clause shall not 
be limited in any way by, and shall be interpreted without reference to, 
any other clause of this contract, including the clause entitled 
Contract Disputes, provided, however, that this clause shall be subject 
to the clauses entitled Covenant Against Contingent Fees, and Audit and 
records--negotiation, and any provisions

[[Page 397]]

that are later added to this contract as required by applicable Federal 
law, including statutes, executive orders and regulations, to be 
included in Nuclear Hazards Indemnity Agreements.
    (i) Civil penalties. The contractor and its subcontractors and 
suppliers who are indemnified under the provisions of this clause are 
subject to civil penalties, pursuant to 234A of the Act, for violations 
of applicable DOE nuclear-safety related rules, regulations, or orders.
    (j) Criminal penalties. Any individual director, officer, or 
employee of the contractor or of its subcontractors and suppliers who 
are indemnified under the provisions of this clause are subject to 
criminal penalties, pursuant to 223(c) of the Act, for knowing and 
willful violation of the Atomic Energy Act of 1954, as amended, and 
applicable DOE nuclear safety-related rules, regulations or orders which 
violation results in, or, if undetected, would have resulted in a 
nuclear incident.
    (k) Inclusion in subcontracts. The contractor shall insert this 
clause in any subcontract which may involve the risk of public 
liability, as that term is defined in the Act and further described in 
paragraph (d)(2) above. However, this clause shall not be included in 
subcontracts in which the subcontractor is subject to Nuclear Regulatory 
Commission (NRC) financial protection requirements under section 170b. 
of the Act or NRC agreements of indemnification under section 170c. or 
k. of the Act for the activities under the subcontract.

                             Effective date

    (  ) See note II below for instructions related to this section on 
Effective Date.

                    Relationship to general indemnity

    (  ) See note III below for instructions related to this section on 
Relationship to General Indemnity.

                             (End of clause)

                                 Note I

    Paragraph (i) of the clause will be replaced with ``Reserved'' in 
contracts specifically exempted from civil penalties by section 234 of 
the Act. That subsection provides that the following DOE contractors are 
not subject to the assessment of civil penalties:
    (1) The University of Chicago (and any subcontractors or suppliers 
thereto) for activities associated with Argonne National Laboratory;
    (2) The University of California (and any subcontractors or 
suppliers thereto) for activities associated with Los Alamos National 
Laboratory, Lawrence Livermore National Laboratory, and Lawrence 
Berkeley National Laboratory;
    (3) American Telephone and Telegraph Company and its subsidiaries 
(and any subcontractors or suppliers thereto) for activities associated 
with Sandia National Laboratories;
    (4) Universities Research Association, Inc. (and any subcontractors 
or suppliers thereto) for activities associated with FERMI National 
Laboratory:
    (5) Princeton University (and any subcontractor or suppliers 
thereto) for activities associated with Princeton Plasma Physics 
Laboratory;
    (6) The Associated Universities, Inc. (and any subcontractors or 
suppliers thereto) for activities associated with the Brookhaven 
National Laboratory; and
    (7) Battelle Memorial Institute (and any subcontractors or suppliers 
thereto) for activities associated with Pacific Northwest Laboratory.

                              (End of note)

                                 Note II

    Contracts with an effective date after the date of (date to be that 
of the Final Rule resulting from the proposed rule herein), do not 
require the effective date provision in this clause. Delete the title.
    Use the EFFECTIVE DATE title and the following language, for those 
contracts:

``(  ) This indemnity agreement shall be applicable with respect to 
          nuclear incidents occurring on or after ____.''
    (1) Those that contained an indemnity pursuant to Public Law 85-840 
prior to August 20, 1988, include the effective date provision above, 
inserting the effective date of the contract modification that replaced 
the Public Law 85-804 indemnity with an interim Price-Anderson based 
indemnity. Pursuant to the Price-Anderson Amendments Act, this 
substitution must have taken place by February 20, 1989.
    (2) Those that contained, and continue to contain, either of the 
previous Nuclear Hazards Indemnity clauses, include the effective date 
provision above, inserting ``August 20, 1988.''
    (3) Those with an effective date between August 20, 1988, and the 
date of the Final Rule, that (a) had ``interim coverage'' or (b) did not 
have ``interim coverage'' but have now been determined to be covered 
under the PAAA, include the effective date provision above, inserting 
the contract effective date.

                                Note III

    The following alternate will be added to the above Nuclear Hazards 
Indemnity Agreement clause for all contracts that contain a general 
authority indemnity pursuant to 950.7101. Caution: Be aware that for 
contracts that will have this provision added which do not contain an 
effective date provision, this

[[Page 398]]

paragraph shall be marked (1). In the event an Effective Date provision 
has been included, it shall be market (m).
``(  ) To the extent that the contractor is compensated by any financial 
          protection, or is indemnified pursuant to this clause, or is 
          effectively relieved of pubic liability by an order or orders 
          limiting same, pursuant to 170e of the Act, the provisions of 
          the clause providing general authority indemnity shall not 
          apply.''

                              (End of note)

[56 FR 57828, Nov. 14, 1991, as amended at 58 FR 32307, June 9, 1993; 61 
FR 21977, May 13, 1996; 61 FR 30823, June 18, 1996]



952.250-71--952.250-72  [Reserved]



952.251-70  Contractor employee travel discounts.

    As prescribed in Subpart 951.70, the following provision/clause will 
be included in all cost-reimbursable solicitations and resulting 
contracts, or contract modifications, as applicable.

            Contractor Employee Travel Discounts (June 1995)

    Consistent with contract-authorized travel requirements, contractor 
employees shall make use of the travel discounts offered to Federal 
travelers, through use of contracted airlines discount air fares, hotels 
and motels lodging rates and car rental companies, when use of such 
discounts would result in lower overall trip costs and the discounted 
services are reasonably available to contractor employees performing 
official Government contract business. Vendors providing these services 
may require that the contractor employee traveling on Government 
business be furnished with a letter of identification signed by the 
authorized contracting officer.
    (a) Contracted airlines. Airlines participating in travel discounts 
are listed in the Federal Travel Directory (FTD), published monthly by 
the General Services Administration (GSA). Regulations governing the use 
of contracted airlines are contained in the Federal Travel Regulation 
(FTR), 41 CFR part 301-15, Travel Management Programs. It stipulates 
that cost-reimbursable contractor employees may obtain discount air 
fares by use of a Government Transportation Request (GTR), Standard Form 
1169, cash or personal credit cards. When the GTR is used, contracting 
officers may issue a blanket GTR for a period of not less than two weeks 
nor more than one month. In unusual circumstances, such as prolonged or 
international travel, the contracting officer may extend the period for 
which a blanket GTR is effective to a maximum of three months. 
Contractors will ensure that their employees traveling under GTR provide 
the GTR number to the contracted airlines for entry on individual 
tickets and on month-end billings to the contractor.
    (b) Hotels/motels. Participating hotels and motels which extend 
discounts are listed in the FTD, which shows rates, facilities, and 
identifies by code those which offer reduced rates to cost-reimbursable 
contractor employees while traveling on official contract business.
    (c) Car rentals. The Military Traffic Management Command (MTMC) 
Department of Defense, negotiates rate agreements with car rental 
companies for special flat rates and unlimited mileage. Participating 
car rental companies which offer these terms to cost-reimbursable 
contractor employees while traveling on official contract business are 
listed in the FTD.
    (d) Procedures for obtaining service. (1) Identification and method 
of payment requirements for participating Federal contracted airlines 
are listed in the FTR. Travel discount air fares may be ordered by the 
issuance of a GTR either directly to the contractor, or to a Scheduled 
Airline Travel Office (SATO) or Federal Travel Management Center (FTMC), 
provided the letter of identification signed by the cognizant 
contracting officer accompanies the order. In appropriate instances, 
such as geographical proximity, contractors may obtain discount air 
fares through a DOE office or a cooperating local travel agency when 
neither a SATO or FTMC is available. Some airlines allow the purchase of 
discounted air fares with cash or credit card.
    (2) In the case of hotel and motel accommodations, reservations may 
be made by the contractor employee directly with the hotel or motel but 
the employee must display, on arrival, the letter of identification and 
any other identification required by the hotel or motel proprietorship.
    (3) For car rentals, generally the same procedures as in (d)(2) 
above will be followed in arranging reservations and obtaining 
discounts.
    (e) Standard letter of identification. Contractors shall prepare for 
the authorizing contracting officer a letter of identification based on 
the following format:

Format for Government Contractors to Qualify for Travel Discounts (To be 
                  typed on agency official letterhead)

To: (Source of ticketing, accommodations or rental)
Subject: Official Travel of Government Contractor
    (Full name of traveler), bearer of this letter, is an employee of 
(company name) which is under contract to this agency under the 
Government contract (contract number). During the period of the contract 
(give dates), the employee is eligible and authorized to use

[[Page 399]]

available discount rates for contract-related travel in accordance with 
your contract and/or agreement with the Federal Government.

(Signature, title and telephone number of the contracting officer)
[54 FR 17737, Apr. 25, 1989; 54 FR 26045, June 21, 1989, as amended at 
59 FR 9109, Feb. 25, 1994; 60 FR 30005, June 7, 1995; 61 FR 41711, Aug. 
9, 1996]

[[Page 400]]



             SUBCHAPTER I--AGENCY SUPPLEMENTARY REGULATIONS





PART 970--DOE MANAGEMENT AND OPERATING CONTRACTS--Table of Contents




Sec.
970.0000  Scope of part.
970.0001  [Reserved]

                        Subpart 970.03 [Reserved]

                 Subpart 970.04--Administrative Matters

970.0404  Safeguarding classified information.
970.0404-1  Definitions.
970.0404-2  General.
970.0404-3  Responsibilities of contracting officers.
970.0404-4  Contract clauses.
970.0406  [Reserved]
970.0407  Record retention requirements.
970.0407-1  Alternate retention schedules.
970.0407-2  Access to and ownership of records.
970.0407-3  Contract clause.
970.0470  Department of Energy directives.
970.0470-1  General.
970.0470-2  Contract clause.

        Subpart 970.08--Required Sources of Supplies and Services

970.0801  Excess personal property.

                Subpart 970.09--Contractor Qualifications

970.0901  Management controls.
970.0905  Organizational conflicts of interest.

 Subpart 970.10--Specifications, Standards and Other Statement of Work 
                              Descriptions

970.1001  Performance-based contracting.
970.1002  Additional considerations.

               Subpart 970.15--Contracting by Negotiation

970.1507  Make-or-buy plans.
970.1507-1  Policy.
970.1507-2  Requirements.
970.1507-3  Contract clause.
970.1508  Price negotiation.
970.1508-1  Cost or pricing data.
970.1509  Fees for management and operating contracts.
970.1509-1  Fee policy.
970.1509-2  Special considerations--educational institutions.
970.1509-3  Special considerations--nonprofit organizations (other than 
          educational institutions).
970.1509-4  Considerations and techniques for determining fees.
970.1509-5  Limitations.
970.1509-6  Fee base.
970.1509-7  Special equipment purchases.
970.1509-8  Special considerations--award fee.

               Subpart 970.17--Special Contracting Methods

970.1702-1  Term of contract and option to extend.
970.1702-2  Solicitation provision and contract clause.

    Subpart 970.19--Small, Small Disadvantaged and Women-Owned Small 
                            Business Concerns

970.1901  General.

                        Subpart 970.20 [Reserved]

              Subpart 970.22--Application of Labor Policies

970.2201  Basic labor policies.
970.2206  Walsh-Healey Public Contracts Act.
970.2208  Equal employment opportunity.
970.2210  Service Contract Act.
970.2270  Unemployment compensation.
970.2271  Workers' compensation insurance.
970.2272  Conduct of employees and consultants of DOE management and 
          operating contractors.
970.2273  Administrative controls and criteria for application of the 
          Davis-Bacon Act in operational or maintenance activities.
970.2274  Whistleblower protection of contractor employees.
970.2274-1  General.
970.2274-2  Clause.
970.2275  Overtime management.
970.2275-1  General.
970.2275-2  Contract clause.

  Subpart 970.23--Environmental, Conservation, and Occupational Safety 
                                Programs

970.2303  Hazardous materials identification and material safety.
970.2303-1  General.
970.2303-2  Clauses.
970.2304  Use of recovered/recycled materials.
970.2301-1  General.
970.2304-2  Contract clause.
970.2305  Workplace substance abuse programs--management and operating 
          contracts.
970.2305-1  General.
970.2305-2  Applicability.
970.2305-3  Definitions.
970.2305-4  Solicitation provision and contract clause.

[[Page 401]]

970.2305-5  Suspension of payments, termination of contract, and 
          debarment and suspension actions.

                        Subpart 970.25 [Reserved]

              Subpart 970.26--Other Socioeconomic Programs

970.2601  Implementation of Section 3021 of the Energy Policy Act of 
          1992.
970.2602-1  Implementation of Section 3161 of the National Defense 
          Authorization Act for Fiscal Year 1993.
970.2602-2  Contract clause.

              Subpart 970.27--Patents, Data, and Copyrights

970.2701  General.
970.2702  Patent rights.
970.2703  Technology transfer.
970.2704  Patent clauses.
970.2705  Rights in technical data--general.
970.2706  Rights in technical data--procedures.

                   Subpart 970.28--Bonds and Insurance

970.2830  Contract clause.
970.2870  Indemnification.

                          Subpart 970.29--Taxes

970.2901  Exemptions from Federal excise taxes.
970.2902  State and local taxes.
970.2903  Contract clause.

                Subpart 970.30--Cost Accounting Standards

970.3001  General.
970.3001-1  Applicability.
970.3001-2  Limitations.

         Subpart 970.31--Contract Cost Principles and Procedures

970.3100  Scope and applicability of subpart.
970.3100-1  Definitions.
970.3100-2  Responsibilities.
970.3100-3  Deviation.
970.3101  General policy.
970.3101-1  Actual cost basis.
970.3101-2  Direct and indirect costs.
970.3101-3  General basis for reimbursement of costs.
970.3101-4  Cost determination based on audit.
970.3101-5  Contractor's system of accounting.
970.3101-6  Advance understandings on particular cost items.
970.3102  Application of cost principles.
970.3102-1  General and administrative expenses.
970.3102-2  Compensation for personal services.
970.3102-3  Cost of money.
970.3102-4  Depreciation.
970.3102-5  Employee morale, health, welfare, food service, and 
          dormitory costs.
970.3102-6  Facilities (plant and equipment).
970.3102-7  Legislative lobbying costs.
970.3102-8  Membership in trade, business and professional 
          organizations.
970.3102-9  Outside technical and professional consultants.
970.3102-10  Overtime, shift, and holiday premiums.
970.3102-11  Page charges in scientific journals.
970.3102-12  Plant reconversion costs.
970.3102-13  Precontract costs.
970.3102-14  Preparatory and make-ready costs.
970.3102-15  Procurement: Subcontracts, contractor-affiliated sources, 
          and leases.
970.3102-16  Relocation costs.
970.3102-17  Travel costs.
970.3102-18  Special funds in the construction industry.
970.3102-19  Public relations and advertising.
970.3102-20  Cost prohibitions related to legal and other proceedings.
970.3102-21  Fines and penalties.
970.3103  Contract clauses.

                   Subpart 970.32--Contract Financing

970.3201  General.
970.3202  Advance payments.
970.3270  Clauses.
970.3271  Special bank account agreement.

             Subpart 970.36--Construction and A-E Contracts

970.3601  Special construction clause for operating contracts.

             Subpart 970.41--Acquisition of Utility Services

970.4100  General.

                   Subpart 970.45--Government Property

970.4501  Contract clause.

                Subpart 970.49--Termination of Contracts

970.4901  General.
970.4902  Termination clause.

        Subpart 970.51--Use of Government Sources by Contractors

970.5101  Use of Government supply sources.
970.5102  Use of interagency motor pool vehicles and related services.

[[Page 402]]

 Subpart 970.52--Contract Clauses for Management and Operating Contracts

970.5201  General policy.
970.5202  Deviations.
970.5203  Modifications and notes to FAR clauses.
970.5203-1  Covenant against contingent fees.
970.5203-2  [Reserved]
970.5203-3  Buy American Act.
970.5204  Clauses to be used in addition to or in place of the contract 
          clauses set forth in FAR Part 52 and DEAR Part 952.
970.5204-1  Security.
970.5204-2  Integration of environment, safety, and health into work 
          planning and execution.
970.5204-3  Buy American Act--construction materials.
970.5204-4  New Mexico Gross Receipts and Compensating Tax.
970.5204-5  Disclosure of information.
970.5204-6  Nuclear hazards indemnity.
970.5204-7  Protecting the Government's interest when subcontracting 
          with contractors debarred, suspended, or proposed for 
          debarment.
970.5204-8  Indemnity assurance to architect-engineer or supplier prior 
          to operation of a nuclear facility.
970.5204-9  Accounts, records, and inspection.
970.5204-10  Foreign ownership, control, or influence over contractors 
          (FOCI).
970.5204-11  Changes.
970.5204-12  Contractor's organization.
970.5204-13  Allowable costs and fixed-fee (management and operating 
          contracts).
970.5204-14  Allowable costs and fixed-fee (support contracts).
970.5204-15  Obligation of funds.
970.5204-16  Payments and advances.
970.5204-17  Legislative lobbying cost prohibition.
970.5204-18  [Reserved]
970.5204-19  Printing clause for management and operating contracts.
970.5204-20  Management controls.
970.5204-21  Property.
970.5204-22  Contractor purchasing system.
970.5204-23  Taxes.
970.5204-24  Subcontractor cost or pricing data.
970.5204-25  Workmanship and materials.
970.5204-26  [Reserved]
970.5204-27  Consultant or other comparable employment services of 
          contractor employees.
970.5204-28  Assignment.
970.5204-29  Permits or licenses.
970.5204-30  Notice of labor disputes.
970.5204-31  Insurance--litigation and claims.
970.5204-32  [Reserved]
970.5204-33  Priorities and allocations.
970.5204-35  Controls in the national interest.
970.5204-36  Preventing conflicts of interest in university research.
970.5204-37  Statement of work (management and operating contracts).
970.5204-38  Special clause for procurement of construction.
970.5204-39  Acquisition and use of environmentally preferable products 
          and services.
970.5204-40  Technology transfer mission.
970.5204-41  [Reserved]
970.5204-42  Key personnel.
970.5204-43  Other Government contractors.
970.5204-44  Flowdown of contract requirements to subcontracts.
970.5204-45  Termination.
970.5204-48  [Reserved]
970.5204-50  [Reserved]
970.5204-51  [Reserved]
970.5204-52  Foreign travel.
970.5204-53  Contractor employee travel discounts.
970.5204-54  Basic fee and award fee.
970.5204-55  [Reserved]
970.5204-56  [Reserved]
970.5204-57  Agreement regarding workplace substance abuse programs at 
          DOE facilities.
970.5204-58  Workplace substance abuse programs at DOE sites.
970.5204-59  Whistleblower protection for contractor employees.
970.5204-60  Facilities management.
970.5204-61  Cost prohibitions related to legal and other proceedings.
970.5204-62  [Reserved]
970.5204-63  Collective bargaining agreements--management and operating 
          contracts.
970.5204-71  Patent rights--nonprofit management and operating 
          contractors.
970.5204-72  Patent rights--profit-making management and operating 
          contractors.
970.5204-73  Notice regarding options.
970.5204-74  Option to extend the term of the contract.
970.5204-75  Preexisting conditions.
970.5204-76  Make-or-buy-plans.
970.5204-77  Workforce restructuring under Section 3161 of the National 
          Defense Authorization Act for Fiscal Year 1993.
970.5204-78  Laws, regualtions, and DOE directives.
970.5204-79  Access to and ownership of records.
970.5204-80  Overtime management.

        Subpart 970.70--Use of DOE Facilities for Work for Others

970.7000  Mission-oriented solicitation.

     Subpart 970.71--Management and Operating Contractor Purchasing

970.7101  General.
970.7102  DOE responsibility.
970.7103  Contractor purchasing system.

[[Page 403]]

970.7105  Purchasing from contractor-affiliated sources.
970.7108  Review and approval.
970.7109  Advance notification.
970.7110  Nuclear material transfers.

                  Subpart 970.72--Facilities Management

970.7201  Policy.

                   Subpart 970.73 Technology Transfer

970.7310  General.
970.7320  Policy.
970.7330  Contract clause.

    Authority:  Sec. 161 of the Atomic Energy Act of 1954 (42 U.S.C. 
2201), sec. 644 of the Department of Energy Organization Act, Public Law 
95-91 (42 U.S.C. 7254).

    Source:  49 FR 12063, Mar. 28, 1984, unless otherwise noted.



970.0000  Scope of part.

    This part provides Departmental requirements and provisions 
regarding award and administration of management and operating contracts 
as defined at FAR Subpart 17.6 and subpart 917.6 of this chapter. Use of 
a management and operating contract must be authorized by the Secretary, 
Deputy Secretary, or Under Secretary. For administrative convenience, 
the subparts of this part are arranged in the same numeric sequence as 
the parts of the FAR. Thus, for example, requirements regarding small 
business are found at 970.19 and guidance regarding contract clauses is 
found at 970.52. To the extent possible the same subpart section and 
subsection titles of the FAR are applied in this part 970. There are 
some differences for convenience. When there is no specific guidance of 
a FAR part/ section or applicability of a FAR part/section to DOE 
management and operating contracts a subpart or section will not be 
included.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994]



970.0001  [Reserved]



                        Subpart 970.03 [Reserved]



                 Subpart 970.04--Administrative Matters



970.0404  Safeguarding classified information.



970.0404-1  Definitions.

    Classified Information means any information or material that is 
owned by or produced for, or is under the control of the United States 
Government, and determined pursuant to provisions of Executive Order 
12356, April 2, 1982 (47 FR 14874, April 6, 1982), or prior orders, or 
as authorized under the Atomic Energy Act of 1954, as amended, to 
require protection against unauthorized disclosure, and is so 
designated.
    Restricted Data means data which is defined, in section 11, of the 
Atomic Energy Act of 1954, as amended, as ``all data concerning: (1) 
Design, manufacture, or utilization of atomic weapons; (2) the 
production of special nuclear material; or (3) the use of special 
nuclear material in the production of energy, but shall not include data 
declassified or removed from the Restricted Data category pursuant to 
section 142.''
[49 FR 12063, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994]



970.0404-2  General.

    (a) The basis of DOE's security requirements is the Atomic Energy 
Act of 1954, as amended.
    (b) DOE regulations concerning national security information are 
codified at 10 CFR part 1045 and part 710. Supplemental security 
material is found in the DOE Directives system. Foreign ownership, 
control, or influence over contractors as it relates to security and 
discussed at 904.70 also applies to management and operating contracts. 
Regulations pertaining to the protection of restricted data is found 
under 10 CFR part 1016.

[[Page 404]]

    (c) Statutory requirements to be observed in connection with the 
release of Restricted Data to foreign governments are contained in the 
Atomic Energy Act of 1954, Sections 141 and 144.
    (d) Section 148 of the Atomic Energy Act (42 U.S.C. 2168) prohibits 
the unauthorized dissemination of unclassified nuclear information with 
respect to the atomic energy defense programs pertaining to:
    (1) The design of production facilities or utilization facilities;
    (2) Security measures (including security plans, procedures, and 
equipment) for the physical protection of: (i) production or utilization 
facilities, (ii) nuclear material contained in such facilities, or (iii) 
nuclear materials in transit; or
    (3) The design, manufacture, or utilization of any atomic weapon or 
component if the design, manufacture, or utilization of such weapon or 
component was contained in any information declassified or removed from 
the Restricted Data category pursuant to section 142 of the Atomic 
Energy Act.
[49 FR 12063, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9109, Feb. 25, 1994]



970.0404-3  Responsibilities of contracting officers.

    (a) If access to Restricted Data may be required, during the 
solicitation process for a management and operating contract, security 
clearances shall be obtained in accordance with applicable DOE 
Directives in the safeguards and security series.
    (b) Management and operating contracts which may require the 
processing or storage of Restricted Data or Special Nuclear Material 
require application of the applicable DOE Directives in the safeguards 
and security series.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994; 62 
FR 2312, Jan. 16, 1997]



970.0404-4  Contract clauses.

    (a) The security clauses to be used in DOE management and operating 
contracts are found at 970.5204. They are:
    (1) Security and Classification, 970.5204-1. This clause is required 
in management and operating contracts under section 41 (ownership and 
operation of production facilities) of the Atomic Energy Act of 1954, as 
amended; and all management and operating contracts which involve 
classified information.
    (2)-(3) [Reserved]
    (4) Foreign ownership, control, or influence, 970.5204-10. The 
clause is required in all management and operating contracts.
    (b) The clause at 970.5204-5, Disclosure of Information may be used 
in place of the clauses entitled ``Security'' and ``Classification'' in 
contracts for work that are not likely to produce classified information 
or restricted data.
    (c) Include the clause at 952.204-73 in a solicitation for a 
management and operating contract.
    (d) See 904.71 for guidance concerning the prohibition on award of a 
DOE contract under a national security program to a company owned by an 
entity controlled by a foreign government when access to proscribed 
information is required to perform the contract.
[49 FR 12063, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 52 
FR 38426, Oct. 16, 1987; 58 FR 59684, Nov. 10, 1993; 59 FR 24359, May 
11, 1994]



970.0406  [Reserved]



970.0407  Record retention requirements.



970.0407-1  Alternate retention schedules.

    Records produced under the Department's contracts involving 
management and operation responsibilities relative to DOE-owned or -
leased facilities are to be retained and disposed of in accordance with 
the requirements of DOE Order 1324.5B, Records Management Program and 
DOE Records Schedules, (see current version) rather than those set forth 
at FAR subpart 4.7, Contractor Records Retention.
[62 FR 34862, June 27, 1997]



970.0407-2  Access to and ownership of records.

    Contracting officers may agree to contractor ownership of the 
categories of records designated in the instruction in paragraph (b) of 
48 CFR (DEAR) 970.5204-79, Access to and Ownership of Records, provided 
the Government's

[[Page 405]]

rights to inspect, copy, and audit these records are not limited. These 
rights must be retained by the Government in order to carry out the 
Department's legal responsibilities under the Atomic Energy Act and 
other statutes in overseeing its contractors, including compliance with 
the Department's health and safety and reporting requirements, and to 
protect the public interest.
[62 FR 34862, June 27, 1997]



970.0407-3  Contract clause.

    The contracting officer shall insert the clause at 48 CFR (DEAR) 
970.5204-79, Access to and Ownership of records, in management and 
operating contracts.
[62 FR 34862, June 27, 1997]



970.0470  Department of Energy directives.



970.0470-1  General.

    (a) The Department of Energy Directives System is a system of 
instructions, including orders, notices, manuals, guides, and standards, 
for Departmental elements. In certain circumstances, requirements 
contained in these directives may apply to a contractor through 
operation of a contract clause. Program and requirements personnel are 
responsible for identifying requirements in the Directives System 
applicable to a contract, and developing a list of applicable 
requirements and providing it to the contracting officer for inclusion 
in the contract.
    (b) Where directives requirements are established using either the 
Standards/Requirements Identification Process or the Work Smart 
Standards Process, the applicable process should also be used to 
establish the environment, safety, and health portion of the list 
identified in paragraph (a) of this section.
[62 FR 34862, June 27, 1997]



970.0470-2  Contract clause.

    The contracting officer shall insert the clause at DEAR 970.5204-78, 
Laws, Regulations, and DOE Directives, in management and operating 
contracts.
[62 FR 34862, June 27, 1997]



        Subpart 970.08--Required Sources of Supplies and Services



970.0801  Excess personal property.

    The provisions of FAR Subpart 8.1, FPMR 41 CFR 101-43, and DOE-PMR 
41 CFR 109-43 apply.



                Subpart 970.09--Contractor Qualifications



970.0901  Management controls.

    (a) As a management and operating contractor, the contractor shall 
develop and maintain systems of management and quality control to 
discourage waste, abuse, and fraud; and to ensure components, products, 
and services provided DOE meet's the specifications.
    (b) As a part of the required overall management structure, the 
contractor must maintain management control systems which:
    (1) Are documented and satisfactory to DOE;
    (2) Ensure that all levels of management are accountable for 
effective management systems and internal controls within their areas of 
assigned responsibility;
    (3) Cover both programmatic and administrative functions;
    (4) Provide reasonable assurance that Government resources are 
safeguarded against theft, fraud, waste, and unauthorized use;
    (5) Promote efficient and effective operations;
    (6) Ensure that all obligations and costs incurred are in compliance 
with the contract's terms and conditions and intended purposes;
    (7) Properly record, manage, and report all revenues, expenditures, 
transactions and assets;
    (8) Maintain financial, statistical and other reports necessary to 
maintain accurate, reliable, and timely accountability and management 
controls;
    (9) Are periodically reviewed to ensure they are adequate to provide 
reasonable assurance that the objectives of the system are being 
accomplished and that these controls are working effectively;

[[Page 406]]

    (10) Are in accordance with the Comptroller General's standards for 
internal controls, as set forth in the General Accounting Office Policy 
and Procedures Manual For Guidance To Federal Agencies, chapter 3 of 
title 2 (Oct 1984), as amended.
    (c) As a management and operating contractor, the contractor shall 
also develop and maintain a baseline program of quality assurance that 
will implement documented performance and quality standards, and 
management controls and assessment techniques to ensure components, 
services, and products meet DOE's, design agency and other governing and 
applicable specifications.
[56 FR 65448, Dec. 17, 1991]



970.0905  Organizational conflicts of interest.

    Management and operating contracts shall contain an organizational 
conflict of interest clause substantially similar to the clause at 48 
CFR 952.209-72 and appropriate to the statement of work of the 
individual contract. In addition, the contracting officer shall assure 
that the clause contains appropriate restraints on intra-corporate 
relations between the contractor's organization and personnel operating 
the Department's facility and its parent corporate body and affiliates, 
including personnel access to the facility, technical transfer of 
information from the facility, and the availability from the facility of 
other advantages flowing from performance of the contract. The 
Contracting Officer is responsible for ensuring that M&O contractors 
adopt policies and procedures in the award of the subcontracts that will 
meet the Department's need to safeguard against biased work product and 
an unfair competitive advantage. To this end, the organizational 
conflicts of interest clause in the management and operating contract 
shall include Alternate I.
[62 FR 40753, July 30, 1997]



 Subpart 970.10--Specifications, Standards and Other Statement of Work 
                              Descriptions



970.1001   Performance-based contracting.

    (a) It is the policy of the Department of Energy to use, to the 
maximum extent practicable, performance-based contracting methods in its 
management and operating contracts. Office of Federal Procurement Policy 
Letter 91-2 provides guidance concerning the development and use of 
performance-based contracting concepts and methodologies that may be 
generally applied to management and operating contracts. Performance-
based contracts: describe performance requirements in terms of results 
rather than methods of accomplishing the work; use measurable (i.e., 
terms of quality, timeliness, quantity) performance standards and 
objectives and quality assurance surveillance plans; provide performance 
incentives (positive or negative) where appropriate; and specify 
procedures for award or incentive fee reduction when work activities are 
not performed or do not meet contract requirements.
    (b) The use of performance-based statements of work, where feasible, 
is the preferred method for establishing work requirements. Such 
statements of work and other documents used to establish work 
requirements (such as work authorization directives) should describe 
performance requirements and expectations in terms of outcome, results, 
or final work products, as opposed to methods, processes, or design.
    (c) Contract performance requirements and expectations should be 
consistent with the Department's strategic planning goals and 
objectives, as made applicable to the site or facility through 
Departmental programmatic and financial planning processes. Measurable 
performance criteria, objective measures, and where appropriate, 
performance incentives, shall be structured to correspond to the 
performance

[[Page 407]]

requirements established in the statement of work and other documents 
used to establish work requirements.
    (d) Quality assurance surveillance plans shall be developed to 
facilitate the assessment of contractor performance and ensure the 
appropriateness of any award or incentive fee payment. Such plans shall 
be tailored to the contract performance objectives, criteria, and 
measures, and shall, to the maximum extent practicable, focus on the 
level of performance required by the performance objectives rather than 
the methodology used by the contractor to achieve that level of 
performance.
[62 FR 34862, June 27, 1997]



970.1002  Additional considerations.

    (a) While it is not feasible to set forth standard language which 
would apply to every contract situation, language must be designed for 
inclusion in a management and operating contract to describe clearly the 
work being undertaken; the controls, as appropriate, to be exercised by 
DOE over the performance of that work; and the relationship contemplated 
between the parties.
    (b) The language shall also include the following with respect to 
subcontracting performance of the work described pursuant to (a) of this 
section: ``The contractor shall, when directed by DOE and may, but only 
when authorized by DOE, enter into subcontracts for the performance of 
any part of the work under this clause''.
    (c) In management and operating contracts when the contractor is 
expected to perform no Davis-Bacon work with his own forces, the special 
clause in 970.5204-38 shall be included in the language.
    (d) The provisions required above shall be set forth in a Statement 
of work clause to be included in the contract.



               Subpart 970.15--Contracting by Negotiation



970.1507  Make-or-buy plans.



970.1507-1  Policy.

    (a) Contracting officers shall require management and operating 
contractors to develop and implement make-or-buy plans that establish a 
preference for providing supplies or services (including construction 
and construction management) on a least-cost basis, subject to program 
specific make-or-buy criteria. The emphasis of this make-or-buy 
structure is to eliminate bias for in-house performance where an 
activity may be performed at less cost or otherwise more efficiently 
through subcontracting.
    (b) A work activity, supply or service is provided at ``least cost'' 
when, after consideration of a variety of appropriate programmatic, 
business, and financial factors, it is concluded that performance by 
either ``in-house'' resources or by contracting out is likely to provide 
the property or service at the lowest overall cost. Programmatic factors 
include, but are not limited to, program specific make-or-buy criteria 
established by the Department of Energy, the impact of a ``make'' or a 
``buy'' decision on mission accomplishment, and anticipated changes to 
the mission of the facility or site. Business factors pertain to such 
elements as market conditions, past experience in obtaining similar 
supplies or services, and overall operational efficiencies that might be 
available through either in-house performance or contracting out. Among 
the financial factors that may be considered to determine a least-cost 
alternative in a make-or-buy analysis are both recurring and one-time 
costs attributable to either retaining or contracting out a particular 
item, financial risk, and the anticipated contract price.
    (c) In developing and implementing its make-or-buy plan, a 
contractor shall be required to assess subcontracting opportunities and 
implement subcontracting decisions in accordance with the following:
    (1) The contractor shall conduct internal productivity improvement 
and cost-reduction programs so that in-house performance options can be 
made more efficient and cost-effective.
    (2) The contractor shall consider subcontracting opportunities with 
the maximum practicable regard for open

[[Page 408]]

communications with potentially affected employees and their 
representatives. Similarly, a contractor will communicate its plans, 
activities, cost-benefit analyses, and decisions with those stakeholders 
likely to be affected by such decisions, including representatives of 
the community and local businesses.
[62 FR 34863, June 27, 1997]



970.1507-2  Requirements.

    (a) Development of program-specific make-or-buy criteria. DOE 
program offices responsible for the work conducted at the facility or 
site shall develop program specific make-or-buy criteria. Program 
specific make-or-buy criteria are those factors that reflect specific 
mission or program objectives (including operational efficiency, 
contractor diversity, environment, safety and health, work force 
displacement and restructuring, and collective bargaining agreements) 
and that, upon their application to a specific work effort, would 
override a decision based on a purely economic rationale. These criteria 
are to be used to assess each work effort identified in a facility's or 
site's make-or-buy plan to determine the appropriateness of a 
contractor's make-or-buy decisions. Program specific make-or-buy 
criteria shall be provided to the contractor for use in developing a 
make-or-buy plan for the facility, site, or specific program, as 
appropriate.
    (b) Make-or-buy plan property and services. Supplies or services 
estimated to cost less than one (1) percent of the estimated total 
operating cost for a year or $1 million for the same year, whichever is 
less, need not be included in the contractor's make-or-buy plan. 
However, adjustments may be made to these thresholds where programmatic 
or cost considerations would indicate that a particular supply or 
service should be included in the make-or-buy plan.
    (c) Competitive solicitation requirements. (1) To the extent 
practicable, a competitive solicitation for the management and operation 
of a Department of Energy facility or site should:
    (i) Identify those programs, projects, work areas, functions or 
services that the Department intends for the successful offeror to 
include in any make-or-buy plan; and
    (ii) Require the submission of a preliminary make-or-buy plan for 
the period of performance of the contract from each offeror as part of 
its proposal submitted in response to the competitive solicitation.
    (2) If the requirement for each offeror to submit a preliminary 
make-or-buy plan as part of its proposal is impractical or otherwise 
incompatible with the acquisition strategy, consideration should be 
given to structuring the evaluation criteria for the competitive 
solicitation in such a manner as to permit the evaluation of an 
offeror's approach to conducting its make-or-buy program within the 
context of the contractual requirements.
    (3) The successful offeror's preliminary make-or-buy plan shall be 
submitted for final approval within 180 days after contract award, 
consistent with the requirements of 48 CFR (DEAR) 970.5204-76(c), Make-
or-buy Plan.
    (d) Evaluation of the contractor's make-or-buy plan. In evaluating 
the contractor's make-or-buy plan, the contracting officer shall 
consider the following factors:
    (1) The program specific make-or-buy criteria (such as operational 
efficiency, contractor diversity, environment, safety and health, work 
force displacement and restructuring, and collective bargaining 
agreements) with particular attention to the effect of a ``buy'' 
decision on the contractor's ability to maintain core competencies 
needed to accomplish mission-related program and projects;
    (2) The impact of a ``make'' or ``buy'' decision on contract cost, 
schedule, and performance and financial risk;
    (3) The potential impact of a ``make'' or ``buy'' decision on known 
future mission or program activities at the facility or site;
    (4) Past experience at the facility or site regarding ``make-or-
buy'' decisions for the same, or similar, supplies or services;
    (5) Consistency with the contractor's approved subcontracting plan, 
as required by the clause entitled ``Small, Small Disadvantaged and 
Women-Owned Small Business Subcontracting Plan (FAR 52.219-9), of the 
contract and

[[Page 409]]

implementation of Section 3021 of the Energy Policy Act of 1992.
    (6) Local market conditions, including contractor work force 
displacement and the availability of firms that can meet the work 
requirements with regard to quality, quantity, cost, and timeliness;
    (7) Where the construction of new or additional facilities is 
required, that the cost of such facilities is in the Government's best 
interest when compared to subcontracting or privatization alternatives; 
and
    (8) Whether all relevant requirements and costs of performing the 
work by the contractor and through subcontracting are considered and any 
different requirements for the same work are reconciled.
    (e) Approval. The contracting officer shall approve all plans and 
revisions thereto. Once approved, a make-or-buy plan shall remain 
effective for the term of the contract (up to a period of five years), 
unless circumstances warrant a change.
    (f) Administration. The contractor's performance against the 
approved make-or-buy plan shall be monitored to ensure that:
    (1) The contractor is complying with the plan;
    (2) Items identified for deferral decisions are addressed in a 
timely manner; and
    (3) The contractor periodically updates the make-or-buy plan based 
on changed circumstances or significant new work.
[62 FR 34863, June 27, 1997]



970.1507-3  Contract clause.

    The contracting officer shall insert the clause at 48 CFR (DEAR) 
970.5204-76, Make-or-Buy Plan, in management and operating contracts.
[62 FR 34864, June 27, 1997]



970.1508  Price negotiation.

    (a) Management and operating contract prices (fee) and DOE 
obligations to support contract performance shall be governed by:
    (1) The level of activity authorized and the amount of funds 
appropriated for DOE approved programs by specific program legislation;
    (2) Congressional budget and reporting limitations;
    (3) The amount of funds apportioned to DOE;
    (4) The amount of obligational authority allotted to program 
officials and Approved Funding Program limitations; and
    (5) The amount of funds actually available to the DOE operating 
activity as determined in accordance with applicable financial 
regulations and directives.
    (b) Funds shall be obligated and made available by contract 
provision or modification after the funds become available for 
obligation for payment to support performance of DOE approved projects, 
tasks, work authorizations, or services.
    (c) Management and operating contracts shall contain appropriate 
provisions to limit contractor expenditures to the overall amount of 
funds available and obligated. The clause at 970.5204-15 shall be used 
for this purpose.



970.1508-1  Cost or pricing data.

    The certification requirements of FAR 15.804-2, are not applied to 
DOE cost-reimbursement management and operating contracts.
[49 FR 12063, Mar. 28, 1984, as amended at 53 FR 24231, June 27, 1988]



970.1509  Fees for management and operating contracts.



970.1509-1  Fee policy.

    (a) DOE management and operating contractors, except educational 
institutions, may be paid a fee. The fee for a management and operating 
contract shall be an amount commensurate with the difficulty of the work 
and the level of required skills, demonstrated excellence in 
performance, and where applicable, an amount which recognizes contractor 
contributions or utilizations of their own facilities or other 
investment capital.
    (b) Fee objectives and amounts are to be determined for each 
contract. Standard fees or across the board agreements will not be used 
or made. Due to the nature of funding management and operating 
contracts, it is anticipated that fees shall be established

[[Page 410]]

in accordance with the funding cycle; however, a longer period may be 
used, particularly for production efforts.
    (c) Fee amounts payable on contracts for administration, management, 
operation, and on-site support of Government-owned facilities shall be 
established in accordance with this part. Amounts payable shall not 
exceed maximum amounts derived from the appropriate fee schedule 
established for this purpose. Request to pay fees in excess of the 
maximum will be sent to the Procurement Executive, for review and 
approval.
    (d) Maximum fees for those management and operating contracts that 
provide support services shall be determined using the schedule(s) most 
closely related to the service(s) to be performed. This may be either 
the production and/or R&D schedules (in some cases this could be both 
schedules) or the maximum fee schedules for construction or construction 
management cited in 915.971. If architect-engineer services are 
involved, the weighted guidelines, profit-fee technique cited in 915.970 
shall be applied.
    (e) When a contract subject to this part requires a contractor to 
use its own facilities or equipment, or other resources to make its own 
cost investment for contract performance; e.g., when there is no letter-
of-credit financing, consideration will be given to approval of fee 
amounts based on assigning weights to appropriate fee factors. The 
weighted guidelines factors developed in 915.970 may be applied for this 
purpose. However maximum fees as are discussed in 970.1509-1(c) and (d) 
shall not be exceeded without the Procurement Executives approval.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994]



970.1509-2  Special considerations--educational institutions.

    (a) It is DOE policy to compensate educational institutions 
consistent with the level of financial and management risk they assume 
in connection with their work for the Department.
    (b) Notwithstanding paragraph (a) of this section it may be, under 
special circumstances, permissible to reimburse or pay a management 
allowance to any educational institution provided such allowance can be 
justified and has the approval of the Head of the Contracting Activity.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994; 62 
FR 34864, June 27, 1997]



970.1509-3  Special consideration--nonprofit organizations (other than educational institutions).

    (a) Unless there is reason to do otherwise, it is the general policy 
of DOE to pay fees for a mangement and operating contract with a 
nonprofit organization; however, it is a matter of negotiation whether a 
fee will be paid in a given case.
    (b) In computing the amounts to be paid, the tax status of the 
nonprofit organization should be considered. It is difficult to 
establish the degree to which the fee contributes to an organization's 
overall net profit since the fee compensates for certain unallowable 
costs and certain general and administrative expenses. It should be 
assumed, however, there is an element of profit in the fees paid under 
management and operating contracts.
    (c) In order to assure consideration of the tax benefits of 
nonprofit organizations the maximum payable fixed fee cited in the fee 
schedules of this subpart should be reduced by at least 25%. However, 
depending upon the circumstances and with appropriate justification, 
fees may be paid between this reduced amount and the fee amount 
established by the fee schedule.



970.1509-4  Considerations and techniques for determining fees.

    (a) The intent of the fee policy stated in 970.1509-1 reflects 
recognition that a fee is remuneration to contractors for the 
entrepreneurial function of organizing and managing resources, the use 
of contractor resources (including capital resources), and the 
assumption of risk that all incurred costs (operating and capital) may 
not be reimbursable.
    (b) Use of a purely cost-based structured approach for determining 
fee objectives and amounts for typical DOE management and operating 
contracts is inappropriate considering the limited level of contractor 
cost, capital goods, and operating capital outlays

[[Page 411]]

for performance of such contracts. Instead of being solely cost-based, 
the desirable approach calls for a structure that allows judgmental 
evaluation and consideration of such significant factors, as outlined 
below, and the selection of and assignment of appropriate fee values 
therefor:
    (1) Management risk relating to performance, including: (i) The 
quality and diversity of principal work tasks required to do the job, 
(ii) the labor intensity of the job, (iii) the special control problems, 
and (iv) the advance planning, forecasting and other such requirements;
    (2) The presence or absence of financial risk, including the type 
and terms of the contract;
    (3) The relative difficulty of work, including consideration of 
technical and administrative knowledge, skill, experience and clarity of 
technical specifications;
    (4) Degree and amount of contract work required to be performed by 
and with the contractor's own resources, including the extent to which 
the contractor contributes plant, equipment, computers, or working 
capital (labor, etc.);
    (5) Duration of project;
    (6) Size and operation (number of locations, plants, differing 
operations, etc.);
    (7) Influence of alternative investment opportunities available to 
the contractor (i.e., the extent to which undertaking a task for the 
Government displaces a contractor's opportunity to make a profit with 
the same staff and equipment in some other field of activity).
    (8) The relationship of a proposed fee to fees being paid for 
similar work;
    (9) The extent to which the activity contemplated is fundamentally a 
service being furnished to the Government or is an activity in which the 
contractor has substantial independent interest, a factor especially 
pertinent to research work which is closely allied to a contractor's own 
program and to operations which involve furnishing research facilities 
which would otherwise not be available because of their large cost;
    (10) Benefits which may accrue to the contractor from gaining 
experience and knowledge of how to do something, from establishing or 
enhancing a reputation, or from being enabled to hold or expand a staff 
whose loyalties are primarily to the contractor; and
    (11) Other special considerations, including support of Government 
programs such as those relating to small and minority business in 
subcontracting, energy conservation, etc.
    (c) The fee objective and amount for a particular negotiation is 
established by judgmental considerations of the above factors, assigning 
fee values as deemed appropriate for each factor, and totaling the 
resulting amounts.
    (d) In recognition of the complexities of this fee determination 
process, and to assist in promoting a reasonable degree of consistency 
and uniformity in its application, the fee schedules in 970.1509-5 set 
forth the maximum amounts of fee that contracting activities are allowed 
to award for a particular transaction without obtaining prior approval 
of the Procurement Executive. In addition the fee amount established in 
accordance with 970.1509-4 (a), (b) and (c) shall not be exceeded 
without prior approval of the Procurement Executive. To facilitate 
application of the schedules to a contract, the payable fee amounts 
thereunder are related to the total expected level of cost expenditures 
under the contract which is defined as the fee base.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994]



970.1509-5  Limitations.

    (a) Fee schedules representing the maximum allowable fee to be paid 
under operating and management contracts have been established for the 
following management and operating contract tasks or efforts.
    (1) Production/Manufacturing and
    (2) Research and Development
    (b) The applicable schedules and maximum fees are:

                           Production Efforts                           
------------------------------------------------------------------------
                                            Fee        Fee       Incr.  
           Fee base (dollars)            (dollars)  (percent)  (percent)
------------------------------------------------------------------------
Up to $1 Million.......................  .........  .........      7.00 
1,000,000..............................     70,000      7.00       6.20 
3,000,000..............................    194,000      6.47       5.55 
5,000,000..............................    305,000      6.10       4.48 
10,000,000.............................    529,000      5.29       3.88 

[[Page 412]]

                                                                        
15,000,000.............................    723,000      4.82       3.39 
25,000,000.............................  1,062,000      4.25       3.06 
40,000,000.............................  1,521,000      3,80       2.67 
60,000,000.............................  2,054,000      3.42       2.35 
80,000,000.............................  2,524,000      3.16       2.14 
100,000,000............................  2,952,000      2.95       1.32 
150,000,000............................  3,613,000      2.41       1.02 
200,000,000............................  4,123,000      2.06       0.56 
300,000,000............................  4,678,000      1.56       0.48 
400,000,000............................  5,162,000      1.29       0.41 
500,000,000............................  5,574,000      1.11   .........
Over $500 million......................  5,574,000  .........  \1\ 0.41 
------------------------------------------------------------------------
\1\ 0.41% excess over $500 million.                                     


                    Research and Development Efforts                    
------------------------------------------------------------------------
                                            Fee        Fee       Incr.  
           Fee base (dollars)            (dollars)  (percent)  (percent)
------------------------------------------------------------------------
25,000.................................      2,500     10.00      10.00 
50,000.................................      5,000     10.00      10.00 
100,000................................     10,000     10.00       8.00 
200,000................................     18,000      9.00       8.00 
400,000................................     34,000      8.50       7.50 
600,000................................     49,000      8.17       7.00 
800,000................................     63,000      7.88       7.00 
1,000,000..............................     77,000      7.70       6.40 
3,000,000..............................    205,000      6.83       6.25 
5,000,000..............................    330,000      6.60       5.68 
10,000,000.............................    614,000      6.14       5.22 
15,000,000.............................    875,000      5.83       4.43 
25,000,000.............................  1,318,000      5.27       3.86 
40,000,000.............................  1,897,000      4.74       3.38 
60,000,000.............................  2,572,000      4.29       2.99 
80,000,000.............................  3,170,000      3.96       2.46 
100,000,000............................  3,662,000      3.66       1.54 
150,000,000............................  4,434,000      2.96       1.04 
200,000,000............................  4,955,000      2.48       0.61 
300,000,000............................  5,561,000      1.85       0.53 
400,000,000............................  6,095,000      1.52       0.46 
500,000,000............................  6,556,000      1.31   .........
Over $500 million......................  6,556,000  .........  \1\ 0.46 
------------------------------------------------------------------------
\1\ 0.46% excess over $500 million.                                     

[49 FR 12063, Mar. 28, 1984, as amended at 56 FR 28102, June 19, 1991]



970.1509-6  Fee base.

    (a) The fee base is an estimate of necessary allowable costs to 
which a fee factor has been applied to determine the maximum fee 
allowance. It represents the cost of the production or R&D work to be 
performed, exclusive of the cost of source and special nuclear 
materials; estimated costs of land, buildings and facilities whether to 
be leased, purchased or constructed; depreciation of Government 
facilities; and any estimate of effort for which a separate fee is to be 
negotiated.
    (b) The fee base, in addition to the above adjustments, shall 
exclude:
    (1) Any part of the following types of costs which are of such 
magnitude or nature as to distort the technical and management effort 
actually required of the contractor:
    (i) Estimated cost of capital equipment (other than special 
equipment) which the contractor procures by subcontract;
    (ii) Estimated cost or price of subcontracts and other major 
contractor procurements; and
    (iii) Other similar costs.
    (2) Special equipment as defined in 970.1509-7.
    (3) Estimated cost of Government-furnished materials, services and 
equipment;
    (4) All estimates of costs not directly incurred by or reimbursed to 
the operating contractor;
    (5) Estimates of home office or corporate general and administrative 
expenses that shall be reimbursed through the operating contract;
    (6) Estimates of any independent research and development cost or 
bid and proposal expenses that may be approved under the operating 
contract.
    (c) In calculating the fee base for application of the production 
schedule, the estimated cost of research and development work and of 
process development work which goes beyond normal technical support 
required to ensure continuity of operation shall be excluded. The 
maximum fee for such R&D and process development work is calculated 
separately, starting at the beginning of the R&D schedule.
    (d) The schedules in this part are not intended to reflect 
compensation for unusual architect-engineer or construction services 
provided by the management and operating contractor. Such services are 
normally covered by special agreements based on the policies applying to 
architect-engineer or construction contracts. Fees paid for such 
services shall be in addition to the operating fees and should be 
calculated using the provisions of 915.9 relating to architect-engineer 
or construction fees.
    (e) The fee schedules provide the maximum fees payable within the 
authority of the Head of the Contracting Activity. There may be times 
however, when the fee schedule does not reflect

[[Page 413]]

an adequate compensation to the contractor (such as the use of its own 
facilities and capital). Proposals to compensate a contractor in excess 
of the maximum fee schedules shall be submitted to the Procurement 
Executive. Requests should contain documentation and state specifically 
why the contractor is entitled to additional fees. (See also, 970.1509-
1(c)).
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9109, Feb. 25, 1994]



970.1509-7  Special equipment purchases.

    (a) Special equipment is sometimes procured in conjunction with 
management and operating contracts. When a contractor procures special 
equipment, the DOE negotiating official shall determine separate fees 
for the equipment and use the schedule in 915.971-5(h).
    (b) In determining appropriate fees, factors such as complexity of 
equipment, ratio of procurement transactions to volume of equipment to 
be purchased and completeness of services should be considered. Where 
possible, the reasonableness of the fees should be checked by their 
relationship to actual costs of comparable procurement services.
    (c) The maximum allowable fee for such services shall not exceed the 
fee schedule set forth in 915.971-5(h) for such services as performed by 
construction contractors. The fee is based on the estimated price of the 
equipment being purchased.
    (d) For purposes of this part, special equipment is equipment for 
which the purchase price is of such a magnitude compared to the cost of 
installation as to distort the amount of technical direction and 
management effort required of the contractor. Generally, special 
equipment is considered to be a capital-asset-type of equipment 
(typically equipment costing more than $1,000 and having a service life 
of more than two years) for which the cost of installation and handling 
(including unloading, hauling and warehousing) is 5%, or less, of the 
purchase price of the equipment. However, the determination of specific 
items of equipment in this category requires application of judgment and 
careful study of the circumstances involved in each project. This 
category of equipment would generally include:
    (1) Major items of prefabricated process or research equipment.
    (2) Major items of preassembled equipment such as packaged boilers, 
generators, machine tools, and large electrical equipment. In some 
cases, it would also include special apparatus or devices such as 
reactor vessels and reactor charging machines.
[49 FR 12063, Mar. 28, 1984, as amended at 58 FR 32308, June 9, 1993]



970.1509-8  Special considerations--award fee.

    (a) When a management and operating contract is to be awarded on an 
award-fee basis, several special considerations are appropriate.
    (b) In management and operating contracts, the basic fee portion of 
the fee negotiation objective shall be established equal to what would 
otherwise have been the applicable fixed fee established in accordance 
with 970.1509-4. This basic fee includes a 50% base fee and a 50% ``at 
risk fee.'' No variations from this objective are authorized without the 
prior approval of the Procurement Executive. The basic fee shall be paid 
in equal monthly installments, in accordance with the clause at 
970.5204-16, Payments and Advances. However, in the event the 
contractor's performance is judged by the Fee Determination Official to 
fall into the performance categories of Marginal or Unsatisfactory, as 
those terms are defined in subparagraph (d) of this section, the 
contractor shall be required to refund to the Government up to 50% of 
the basic fee paid for that evaluation period at a rate of 5% for each 
performance point below 76, as shown in the table in subparagraph (d) of 
this section.
    (c) The award fee portion of the fee objective for a management and 
operating contract shall be established for each contract using the 
following formula:

Basic Fee Amount X (multiplied by the) Applicable Award Fee Factor. The 
applicable award fee factor shall be established according to the 
following category placements as set forth below:

Defense Facility--A

[[Page 414]]

Defense Facility--B
Enrichment Plant
Miscellaneous

Individual DOE facilities which are operated under award fee 
arrangements will be assigned to each category by the Procurement 
Executive, whose designee shall distribute a list of such assignments to 
all Heads of Contracting Activities (HCAs). In assigning facilities to 
categories, the Procurement Executive will consider the factors listed 
below, to determine the risks--technical, management, and financial--
which the contractor will assume in fulfilling the contract 
requirements. Contracts which involve higher levels of risks shall be 
placed in higher categories and be eligible for higher award fees. The 
Procurement Executive, or designee, shall review the category 
assignments on a regular basis or upon request by the HCA for a 
particular contract. Reassignments may be made based upon a change in 
contract requirements or changes in any of the following factors:

    (1) Placement of the facility on the EPA's National Priority List 
(NPL). Facilities which are listed on the NPL shall be considered to 
involve higher risks.
    (2) Nature of the contractor's work at the facility. Contracts 
involving the management of facilities listed on the NPL or requiring 
the environmental restoration of NPL sites, shall be considered to 
involve higher risks, whereas contracts involving unrelated work may be 
considered of lesser risk, regardless of NPL designations.
    (3) Size of the facility in relationship to the areas of risk. 
Management of a large facility with a minor site designated on the NPL 
would be considered a lesser risk than management of a small facility 
which includes several major sites listed on the NPL.
    (4) Quantity, complexity and type of Government property for which 
the contractor is responsible. Contracts requiring control over large 
quantities of sensitive Government property shall be considered of 
higher risk than those involving relatively small quantities.
    (5) Exposure to Third-Party Liability. Contract activities which 
expose the contractor to the risk of third-party liability will be 
considered, and such risk assessed accordingly.
    (6) The extent to which the work at the facility presents health and 
safety risks to the workers at the facility and the public.

In considering the above factors, any risks which are indemnified by the 
Government (for example, by the Price-Anderson Act) will not be 
considered as risk to the contractor. Where a single contract involves 
multiple facilities falling into different categories, the basic fee 
amount shall be divided into amounts applicable to the operation of each 
facility before applying the award fee pool factor. The following 
potential award fees shall apply in each category (percent is stated as 
a percentage of the otherwise applicable maximum fixed fee amount) which 
is now the basic fee:

                                                                        
------------------------------------------------------------------------
                                                               Potential
                                         Basic fee  Potential   maximum 
                Category                 (percent)  award fee    total  
                                                    (percent)  (percent)
------------------------------------------------------------------------
Defense Facility--A....................        100        200        300
Defense Facility--B....................        100        150        250
Enrichment Plant.......................        100        150        250
Miscellaneous..........................        100        100        200
------------------------------------------------------------------------

    (d) All management and operating contracts awarded on an award fee 
basis shall incorporate the following performance grading and fee 
conversion system into the contract, by including the system in the 
Performance Evaluation Plan required by the contract clause at 970.5204-
54. The performance grading and fee conversion system consists of a set 
of adjectival grades defined in a narrative form, in terms of 
performance points, and the percentage of available award fee earned as 
follows:

                          Fee Conversion Table                          
       [The contractor's performance shall be evaluated by the Fee      
 Determination Official at the end of each evaluation period, and graded
                   in accordance with the scale below]                  
------------------------------------------------------------------------
                                                                Percent 
                                                                of award
                      Performance score                           fee   
                                                                 earned 
------------------------------------------------------------------------
                         Outstanding                                    
                                                                        
Any score in the Outstanding category will earn 100% of the             
 available award fee                                                    
                                                                        
96 and above.................................................      100.0
                                                                        
--------------------------------------------------------------          
                             Good                                       
95...........................................................       94.0
94...........................................................       88.0
93...........................................................       82.0
92...........................................................       75.0
91...........................................................       68.0
90...........................................................       60.0
89...........................................................       51.0
88...........................................................       43.0
87...........................................................       36.0

[[Page 415]]

                                                                        
86...........................................................       30.0
                                                                        
------------------------------------------------------------------------
                         Satisfactory                                   
85...........................................................       25.0
84...........................................................       20.0
83...........................................................       15.0
82...........................................................       10.0
81...........................................................        5.0
80...........................................................        0.0
79...........................................................        0.0
78...........................................................        0.0
77...........................................................        0.0
76...........................................................        0.0
                                                                        
------------------------------------------------------------------------
                                                                        
                      Performance score                          Percent
                                                                of basic
                                                                     fee
                                                                refunded
                                                                        
--------------------------------------------------------------          
                           Marginal                                     
75...........................................................        5.0
74...........................................................       10.0
73...........................................................       15.0
72...........................................................       20.0
71...........................................................       25.0
70...........................................................       30.0
69...........................................................       35.0
68...........................................................       40.0
67...........................................................       45.0
66...........................................................       50.0
                                                                        
------------------------------------------------------------------------
                        Unsatisfactory                                  
Below 65.....................................................       50.0
------------------------------------------------------------------------

    Performance scores should be rounded to the nearest tenth of a point 
and the percent of award fee determined accordingly (e.g., a score of 
88.4 equals 46.2% of award fee earned).

             Narrative Description of Performance Adjectives

                                                                        
                                                                        
                                            Definition (performance     
              Adjective                          description)           
                                                                        
Outstanding.........................  Performance substantially exceeds 
                                       expected levels of performance.  
                                       Several significant or notable   
                                       achievements exist. No notable   
                                       deficiencies in performance.     
Good................................  Performance exceeds expected      
                                       levels and some notable          
                                       achievements exist. Although some
                                       notable deficiencies may exist,  
                                       no significant deficiencies      
                                       exist.                           
Satisfactory........................  Performance meets expected levels.
                                       Minimum standards are exceeded   
                                       and ``good practices'' are       
                                       evident in contract operations.  
                                       Notable achievements or notable  
                                       deficiencies may or may not      
                                       exist.                           
Marginal............................  Performance is less than expected.
                                       No notable achievements exist;   
                                       however, some notable            
                                       deficiencies exist, or any       
                                       notable achievements which exist 
                                       are more than offset by          
                                       significant or notable           
                                       deficiencies.                    
Unsatisfactory......................  Performance is below minimum      
                                       acceptable levels. Significant   
                                       deficiencies causing severe      
                                       impacts on mission capabilities  
                                       exist. Performance at this level 
                                       in any area mentioned in the     
                                       Performance Evaluation Plan may  
                                       result in a decision by the Fee  
                                       Determination Official to        
                                       withhold all award fees for the  
                                       period.                          
                                                                        

                               Definitions

    Significant: This term indicates a major event or sustained level of 
performance which, due to its importance, has a substantial positive or 
negative impact on the contractor's ability to carry out its mission.
    Notable: This term indicates an event or sustained level of 
performance which is of lesser importance than a ``significant'' event, 
but nonetheless deserves positive or negative recognition.
    (e) Prior approval of the Procurement Executive, is required for 
total fee (basic plus award fee pool) exceeding the guidelines in 
paragraph (c), of this section. Additionally, in the event use of the 
award fee guidelines in paragraph (c), of this section, result in total 
fees which exceed or are expected to exceed the statutory limitations 
imposed by 10 U.S.C. 2306(d) and 41 U.S.C. 254(b), prior approval of the 
Procurement Executive shall be obtained.
    (f) When a management and operating contract is to be awarded on an 
award-fee basis, the contract shall include the clause at 970.5204-54.

[[Page 416]]

    (g) Fee Determination Officials must be careful to ensure that all 
important areas of contract performance are mentioned in the Performance 
Evaluation Plan, even if such areas are not assigned specific weights or 
percentages of award fee.
[49 FR 12063, Mar. 28, 1984, as amended at 54 FR 48614, Nov. 24, 1989; 
56 FR 28102, June 19, 1991; 56 FR 38174, Aug. 12, 1991; 59 FR 9109, Feb. 
25, 1994]



               Subpart 970.17--Special Contracting Methods

    Source:  61 FR 32586, June 24, 1996, unless otherwise noted.



970.1702-1  Term of contract and option to extend.

    (a) Contract term. Effective work performance under a management and 
operating contract is facilitated by the use of a relatively long 
contract term of up to ten (10) years. Accordingly, management and 
operating contracts shall provide for a basic contract term not to 
exceed five (5) years and may include an option(s) to extend the term 
for additional periods; provided, that no one option period exceeds five 
(5) years in duration and the total term of the contract, including any 
options exercised, does not exceed ten (10) years. The specific term of 
the base period and of any options periods shall be determined at the 
time of the authorization to compete or extend the contract. The term 
option as used herein means a unilateral right in the contract by which 
the Government can extend the term of the contract. Accordingly, except 
as may be provided for through the inclusion of an option(s) in the 
contract to extend the term, any extension to continue the contract with 
the incumbent contractor beyond its term shall only occur when such 
extension can be justified under one of the statutory authorities 
identified in FAR 6.302 and when authorized by the Head of the Agency.
    (b) Exercise of option. As part of the review required by FAR 
17.605(b), the contracting officer shall assess whether competing the 
contract will produce a more advantageous offer than exercising the 
option. The incumbent contractor's past performance under the contract, 
the extent to which performance-based management contract provisions are 
present, or can be negotiated into, the contract, and the impact of a 
change in a contractor on the Department's discharge of its programs are 
considerations that shall be addressed in the contracting officer's 
decision that the exercise of the option is in the Government's best 
interest. The contracting officer's decision shall be approved by the 
Procurement Executive and the cognizant Assistant Secretary(s).



970.1702-2  Solicitation provision and contract clause.

    (a) The contracting officer shall insert a provision substantially 
the same as the provision at 48 CFR (DEAR) 970.5204-73, Notice Regarding 
Options, in solicitations when the inclusion of an option to extend the 
term of the contract has been authorized.
    (b) The contracting officer shall insert the clause at 48 CFR (DEAR) 
970.5204-74, Option to extend the term of the contract, when the 
inclusion of an option to extend the term of the contract has been 
authorized.



    Subpart 970.19--Small, Small Disadvantaged and Women-Owned Small 
                            Business Concerns



970.1901  General.

    (a) The clause at FAR 52.219-9 shall be included in management and 
operating contracts.
    (b) Management and operating contracts shall include a 
subcontracting plan which is effective for the term of the contract. 
Goals for the contract shall be negotiated annually when revised funding 
levels are determined. The plan should include provisions for revising 
the goals or any other sections of the plan. Such revisions shall be in 
writing, approved by the contracting officer, and shall be specifically 
made a material part of the contract.
[49 FR 12063, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 52 
FR 38426, Oct. 16, 1987; 53 FR 24231, June 27, 1988; 58 FR 36365, July 
7, 1993]

[[Page 417]]



                        Subpart 970.20 [Reserved]



              Subpart 970.22--Application of Labor Policies



970.2201  Basic labor policies.

    (a) Contracting officers shall in appropriate circumstances, follow 
the guidance in FAR Subpart 22.1 except as provided below in award and 
administration of management and operating contracts.
    (b) The extent of Government ownership of the nation's energy plant 
and materials, and the overriding concerns of national defense and 
security, impose special conditions on personnel and labor relations in 
the energy program, namely, continuity of vital operations at DOE 
installations must be assured; DOE must retain absolute authority on all 
questions of security; DOE reviews labor expenses under management and 
operating contracts as a part of its responsibility for assuring 
judicious expenditure of public funds. It is the intent of DOE, that 
personnel and labor policies throughout the energy program should 
reflect the best experience of American industry in aiming to achieve 
the type of stable labor-management relations essential to the proper 
development of the energy program. The following enunciates the 
principles upon which the DOE policy is based:
    (1) Employment standards. (i) Management and operating contractors 
are expected to bring experienced, proven personnel from their private 
operations to staff key positions on the contract work and to recruit 
other well-qualified personnel as needed. Such personnel should be 
employed and treated during employment without discrimination by reason 
of race, color, religion, sex, or national origin. Contractors shall be 
required to take affirmative action to achieve these objectives.
    (ii) The job qualifications and suitability of prospective employees 
should be established by the contractor prior to employment by careful 
personnel investigations. Such personnel investigations should include, 
as appropriate: A credit check; verification of high school degree/
diploma or degree/diploma granted by an institution of higher learning 
within the last 5 years; contacts with listed personal references; 
contacts with listed employers for the past 3 years (excluding 
employment of less than 60 days duration, part-time employments, and 
craft/union employments); and local law enforcement checks when such 
checks are not prohibited by state or local law, statute, or regulation, 
and when the individual had resided in the jurisdiction where the 
contractor is located. Where a security clearance will be required, the 
applicant's job qualifications and suitability must be established 
before a request is made to DOE for a security clearance. When an 
applicant is being hired specifically for a position which shall require 
a DOE security clearance, the applicant shall not be placed in that 
position prior to the security clearance being granted by the DOE unless 
an exception has been obtained from the Head of the Contracting Activity 
or designee.
    (iii) The contractor is responsible for maintaining satisfactory 
standards for employee qualifications, performance, conduct, and 
business ethics under its own personnel policies.
    (2) Security. On all matters of security at its installations, DOE 
retains absolute authority and neither the security rules nor their 
administration are matters for collective bargaining between management 
and labor. Insofar as DOE security regulations affect the collective 
bargaining process, the security policies and regulations will be made 
known to both parties. To the fullest extent feasible, DOE will consult 
with representatives of management and labor in formulating security 
rules and regulations that affect the collective bargaining process.
    (3) Wages, salaries, and employee benefits. (i) Wages, salaries, and 
employee benefits shall be administered in a manner designated to adapt 
normal industry or university practices and conditions to the contract 
work and to provide for appropriate review by DOE. Area practices, valid 
patterns, and well-established commercial or academic practices of the 
contractors, as appropriate, form the criteria for the establishment and 
adjustment of compensation schedules.

[[Page 418]]

    (ii) The aspects of wages, hours, and working conditions which are 
the substance of collective bargaining in normal organized industries 
will be left to the orderly processes of negotiation and agreement 
between DOE contractor managements and employee representatives with 
maximum possible freedom from Government interference.
    (4) Employee relations. The handling of employee relations on 
contract work, including such matters as the conduct and discipline of 
the work force and the handling of employee grievances, is part of the 
normal management responsibility of the contractor.
    (5) Collective bargaining. (i) DOE review of collective bargaining 
practices will be premised on the view that management's trusteeship for 
the operation of the Government facilities includes the duty to adopt 
practices which are fundamental to the friendly adjustment of disputes, 
and which experience has shown promote orderly collective bargaining 
relationships. Practices inconsistent with this view may be objected to, 
if not found to be otherwise clearly warranted.
    (ii) Consistent with the policy of assuring continuity of operation 
of vital facilities, all collective bargaining agreements at DOE-owned 
facilities should provide that grievances and disputes involving the 
interpretation or application of the agreement will be settled without 
resorting to strike, lockout, or other interruption of normal 
operations. For this purpose, each collective bargaining agreement 
entered into during the period of performance of this contract should 
provide an effective grievance procedure with arbitration as its final 
step, unless the parties mutually agree upon some other method of 
assuring continuity of operation for the term of the collective 
bargaining agreement. The contracting officer shall insert the clauses 
at FAR 52.222-1, Notice to the government of labor disputes, and 
970.5204-63, Collective bargaining agreements--management and operating 
contracts, in all management and operating contracts, and subcontracts 
thereunder, which require continuity of operation at a DOE-owned 
facility.
    (iii) DOE expects its management and operating contractors and the 
unions representing contractor employees to cooperate fully with the 
Federal Mediation and Conciliation Service.
    (6) Personnel training. DOE encourages and supports personnel 
training programs aimed at improving work efficiency or developing 
needed skills which are not otherwise obtainable.
    (7) Working conditions. Accident, fire, health, and occupational 
hazards associated with DOE activities will be held to a practical 
minimum level and controlled in the interest of maintenance of health 
and prevention of accidents. To this end, contractors shall be required 
to maintain comprehensive continuous preventive and protective programs 
appropriate to the particular activities throughout all operations 
subject to DOE control. Appropriate financial protection in case of 
occupational disability must be provided employees on DOE projects.
    (c) Title to payroll and associated records under certain contracts 
for the management and operation of DOE facilities, and for necessary 
miscellaneous construction incidental to the function of these 
facilities, shall vest in the Government. Such records are to be 
disposed of in accordance with DOE directions. For such contracts, the 
Solicitor of Labor has granted a tolerance from the Department of Labor 
Regulations to omit from the prescribed labor clauses the requirement 
for the retention of payrolls and associated records for a period of 
three years after completion of the contract. Under this tolerance, the 
records retention requirements for all labor clauses in the contract and 
the Fair Labor Standards Act is satisfied by disposal of such records in 
accordance with DOE directives.
[49 FR 12063, Mar. 28, 1984, as amended at 58 FR 36152, July 6, 1993; 59 
FR 9109, Feb. 25, 1994]



970.2206  Walsh-Healey Public Contracts Act.

    Because DOE has safety and health standards compatible with those of 
41 CFR part 50-204, the Department of Labor has agreed to accept DOE's 
program for inspection and evaluation of compliance, in lieu of 
establishing its

[[Page 419]]

own program of inspection and evaluation to the extent the Walsh-Healey 
safety and health standards are applicable to operations conducted for 
DOE at Government-owned and/or controlled sites and facilities.
[49 FR 12063, Mar. 28, 1984, as amended at 53 FR 24231, June 27, 1988]



970.2208  Equal employment opportunity.

    The equal employment opportunity provisions of FAR Subpart 22.8 and 
subpart 922.8 of this chapter, including E.O. 11246 and 41 CFR part 60, 
are applicable to DOE management and operating contracts.
[49 FR 12063, Mar. 28, 1984, as amended at 53 FR 24231, June 27, 1988]



970.2210  Service Contract Act.

    The Service Contract Act of 1965 is not applicable to contracts for 
the management and operation of DOE facilities.
[49 FR 12063, Mar. 28, 1984, as amended at 53 FR 24231, June 27, 1988]



970.2270  Unemployment compensation.

    (a) Each state has its own unemployment compensation system to 
provide payments to workers who become unemployed involuntarily and 
through no fault of their own. Funds are provided for unemployment 
compensation benefits through a payroll tax on employers. Most DOE 
contractors are subject to the unemployment compensation tax laws of the 
states in which they are located. It is the policy to assure, both in 
the negotiation and administration of cost-reimbursement type contracts, 
that economical and practical arrangements are made and practiced with 
respect to unemployment compensation.
    (b) Contract exempt from state laws. (1) Some contractors are exempt 
from state unemployment compensation laws, usually on grounds that they 
are nonprofit organizations or subdivisions of State governments. Most 
states, however, permit such employers to elect unemployment 
compensation coverage on a voluntary basis. Under such circumstances, 
all existing or prospective cost-reimbursement contractors shall be 
encouraged to provide unemployment compensation coverage or equivalent 
substitutes.
    (2) It is also DOE policy that, prior to the award or extension of a 
management and operating contract, exempt contractors or prospective 
contractors shall be required to submit to the contracting officer a 
statement that they will either elect coverage or provide equivalent 
substitutes for unemployment compensation, or in the alternative, submit 
evidence that it is impractical to do so. If any exempt contractor or 
prospective contractor submits that it is impractical to elect coverage 
or to provide an equivalent substitute, appropriate Office of Contractor 
Human Resource Management staff shall review that position prior to 
recommending an award or extension of the contract. If there are 
substantial reasons for not electing coverage or for not providing 
equivalent substitutes, a contract may be awarded or extended. 
Headquarters' staff review and recommendation shall be based on such 
factors as:
    (i) The specific provisions of the unemployment compensation law of 
the State;
    (ii) The extent to which the establishment of special conditions on 
DOE work may have an adverse effect on the contractor's general policies 
and operating costs in its private operations;
    (iii) The numerical relationship between the contractor's private 
work force and its employees performing only work for DOE;
    (iv) The contractor's record with respect to work force stability 
and the general outlook with respect to future work force stability;
    (v) In a replacement contractor situation, whether or not the prior 
contractor had coverage or suitable substitutes; and
    (vi) The particular labor relations implications involved.
[49 FR 12063, Mar. 28, 1984, as amended at 58 FR 36365, July 7, 1993]



970.2271  Workers' compensation insurance.

    (a) Policies and requirements--(1) Workers' compensation insurance 
protects employers against liability imposed by workers' compensation 
laws for injury or death to employees arising out of, or in the

[[Page 420]]

course of, their employment. This type of insurance is required by state 
laws unless employers have acceptable programs of self-insurance.
    (2) Special requirements. Certain workers' compensation laws contain 
provisions which result in limiting the protection afforded persons 
subject to such laws. The policy with respect to these limitations as 
they affect persons employed by, management and operating contractors is 
set forth below:
    (i) Elective provisions. Some worker's compensation laws permit an 
employer to elect not to be subject to its provisions. It is DOE policy 
to require these contractors to be subject to workers' compensation laws 
in jurisdictions permitting election.
    (ii) Statutory immunity. Under the provisions of some workers' 
compensation laws, certain types of employers; e.g., nonprofit 
educational institutions, are relieved from liability. If a contractor 
has a statutory option to accept liability, it is DOE policy to require 
the contractor to do so.
    (iii) Limited medical benefits. Some workers' compensation laws 
limit the liability of the employer for medical care to a maximum dollar 
amount or to a specified period of time. In such cases, a contractor's 
workers' compensation insurance policy should contain a standard 
extrastatutory medical coverage endorsement.
    (iv) Limits on occupational disease coverage; and employers' 
liability. Some workers' compensation laws do not provide coverage for 
all occupational diseases. In such situations, a contractor's workers' 
compensation insurance policy should contain voluntary coverage for all 
occupational diseases.
    (3) Contractor ``employees' benefit plan''--self-insurers. The 
policies and requirements set forth in paragraph (2) apply where 
management and operating contractors purchase workers' compensation 
insurance. With respect to self-insured contractors, the objectives 
specified in paragraph (a)(2) also shall be met through primary or 
excess workers' compensation and employers' liability insurance 
policy(ies) or an approved combination thereof. ``Employees' benefit 
plans'' which were established in prior years may be continued to 
contrast termination at existing benefit levels.
    (b) Assignment of responsibilities. (1) Office of Contractor Human 
Resource Management, within the Headquarters procurement organization 
and other officials and the Heads of Contracting Activities, consistent 
with their delegations of responsibility, shall assure management and 
operating contracts are consistent with the policies and requirements of 
paragraph (a), above.
    (2) In discharging assigned responsibility, the Heads of Contracting 
Activities shall:
    (i) Periodically review workers' compensation insurance programs of 
management and operating contractors in the light of applicable workers' 
compensation statutes to assure conformance with the requirements of 
paragraph (a), above;
    (ii) Evaluate the adequacy of coverage of ``self-insured'' workers' 
compensation programs;
    (iii) Provide arrangements for the administration of any existing 
``employees' benefit plans until such plans'' are terminated; and
    (iv) Submit to the Office of Contractor Human Resource Management, 
within the Headquarters procurement organization all proposals for the 
modification of existing ``employees' benefit plans.''
    (3) The Office of Contractor Human Resource Management, within the 
Headquarters procurement organization, is responsible for approving 
management and operating contractor ``employees' benefit plans.''
[49 FR 12063, Mar. 28, 1984, as amended at 58 FR 36365, July 7, 1993; 59 
FR 9110, Feb. 25, 1994]



970.2272  Conduct of employees and consultants of DOE management and operating contractors.

    (a) Scope of subsection. This subsection establishes the policies 
for maintaining satisfactory standards of conduct on the part of 
employees and consultants employed on DOE contract work by its 
management and operating contractors.
    (b) Applicability. (1) These policies are applicable to DOE 
management and operating contractors to the extent that

[[Page 421]]

their contracts with DOE contain provisions making this subsection 
applicable; or instructions have been issued under appropriate 
provisions of their contracts with DOE directing compliance with this 
subpart.
    (2) The contract clause contained in 970.5204-12 requiring the 
contractor to establish such procedures as are necessary to effectively 
implement the provisions of this subsection, subject to the approval of 
the contracting officer, shall be included in all new DOE management and 
operating contracts.
    (3) The contract clause contained in 970.5204-27(a) concerning 
necessary approvals to be obtained by contractor employees before 
performing consultant or similar services for another DOE contractor 
shall be included in:
    (i) All new DOE management and operating contracts except those 
identified in paragraph (b)(4) of this section; and
    (ii) Major modifications (involving change in scope or other 
significant substantive changes) or extensions of existing contracts 
within the foregoing category.
    (4) The contract clause contained in 970.5204-27(b) concerning 
necessary approvals to be obtained by contractor employees before 
performing consultant or similar services for another DOE contractor, or 
in the energy field for another organization, shall be included in:
    (i) All new DOE management and operating contracts for research or 
operations of DOE program work where a substantial portion of the land 
or buildings used for such research or in such operations is owned or 
controlled by the Government; and
    (ii) Major modifications (involving change in scope or other 
significant substantive changes) or extensions of existing contracts 
within the foregoing category.
    (5) Exceptions to the requirements of paragraphs (b)(2), (3), and 
(4) will be permitted only with the approval of the Procurement 
Executive.
    (c) Gratuities. A management and operating contractor or its 
employees or consultants shall not, under circumstances which might 
reasonably be interpreted as an attempt to influence the recipients in 
the conduct of their duties, accept any gratuity or special favor from 
individuals or organizations with whom the contractor is doing business, 
or proposing to do business, in accomplishing the work under the 
contract. Reference should be made to the provisions of 41 U.S.C. 51-54.
    (d) Use of privileged information. Employees and consultants of a 
management and operating contractor shall not use for personal gain or 
make other improper use of privileged information which is acquired in 
connection with their employment on contract work. In this connection, 
the term ``Privileged information'' includes but is not limited to, 
unpublished information relating to technological and scientific 
developments; medical, personnel, or security records of individuals; 
anticipated materials' requirements or pricing action; possible new 
sites for DOE program operations; and knowledge of selections of 
contractors or subcontractors in advance of official announcement.
    (e) Outside employment of contractor employees. Employees of a 
management and operating contractor are entitled to the same rights and 
privileges with respect to outside employment as other citizens. 
Therefore, there is no general prohibition against employees having 
outside employment. However, no employee of a contractor performing work 
on a full-time basis under a DOE management and operating contract may 
engage in employment outside official hours of duty or while on leave if 
such employment will:
    (1) In any manner interfere with the proper and effective 
performance of the duties of the position;
    (2) Appear to create a conflict-of-interest situation, or
    (3) Appear to subject DOE or the contractor to public criticism or 
embarrassment.
    (f) Information statement concerning consultant or other employment 
service. If a consultant or other outside employment service of the 
employee involves the use of information in the area of the employee's 
contract employment, the contractor will be responsible for requiring 
that the employee file with the contractor, an information statement 
containing such information concerning the outside employment as the

[[Page 422]]

contractor may prescribe. As a minimum, the information statement shall 
include a description of any patent agreements that may be involved and 
the following acknowledgement:

    I acknowledge that I have read and am familiar with the published 
policy of the DOE contained in:
    (a) Subpart 970.2272 ``Conduct of employees and consultants of DOE 
management and operating contractors;'' and
    (b) DOE publication entitled, ``Reporting Results of Scientific and 
Technical Work Funded by DOE,'' which states in part that significant 
new results produced in DOE-funded scientific and technical work agree 
not to withhold or delay reporting information acquired through my 
employment with ______ in favor of ______ with whom I have made or am 
contemplating making a consulting agreement. I have also read and am 
familiar with the requirements of my employer's contract with DOE 
relating to patents. To the best of my knowledge or belief, the 
activities to be performed under this consulting agreement will not 
conflict with the policy set forth in 970.5204-27, the patent provisions 
of my employer's contract with DOE, or with the responsibility of my 
employer to report fully and promptly to DOE all significant research 
and development information. If in the course of my activities under 
this consulting agreement, it appears that such a conflict may arise, I 
will promptly notify and consult with my primary employer ______ 
concerning such possible conflict.

    (g) Incompatibility between regular duties and private interests. 
Employees and consultants of a management and operating contractor shall 
not be permitted to make or influence any decisions on behalf of the 
contractor which directly or indirectly affect the interest of the 
Government, if the employee's or consultant's personal concern in the 
matter may be incompatible with the interest of the Government. For 
example: (1) An employee or consultant of a contractor will not 
negotiate, or influence the award of, a subcontract with a company in 
which the individual has an employment relationship or significant 
financial interest; and (2) an employee or consultant of a contractor 
will not be assigned the preparation of an evaluation for DOE or for any 
DOE contractor of some technical aspect of the work of another 
organization with which the individual has an employment relationship, 
or significant financial interest, or which is a competitor of an 
organization (other than the contractor who is the individual's regular 
employer) in which the individual has an employment relationship or 
significant financial interest. The contractor shall be responsible for 
informing employees and consultants that they are expected to disclose 
any incompatibilities between duties performed for the contractor and 
their private interests and to refer undecided questions to the 
contractor.
[49 FR 12063, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9110, Feb. 25, 1994; 59 FR 24359, May 11, 1994]



970.2273  Administrative controls and criteria for application of the Davis-Bacon Act in operational or maintenance activities.

    (a) Particular work items falling within one or more of the 
following criteria normally will be classified as noncovered by the 
Davis-Bacon Act.
    (1) Individual work items estimated to cost $2,000 or less. The 
total dollar amount of the operating contract is not a factor to be 
considered and bears no relation to individual work items classified as 
construction, alteration and/or repair, including painting and 
decorating. However, no item of work, the cost of which is estimated to 
be in excess of $2,000, shall be artificially divided into portions less 
than $2,000 for the purpose of avoiding the application of the Act.
    (2) Work and services that are a part of operational and maintenance 
activities or which, being very closely and directly involved therewith, 
are more in the nature of operational activities than construction, 
alteration, and/or repair work. This includes work and services which 
would involve a material risk to continuity of operations, to life or 
property, or to DOE operating requirements, if performed by persons 
other than the operating contractor's regular production and maintenance 
forces. However, any decision that contracts or work items are 
noncovered for these reasons must be made by the Head of the Contracting 
Activity and the authority to make such a decision cannot be 
redelegated.

[[Page 423]]

    (3) Assembly, modification, setup, installation, replacement, 
removal, rearrangement, connection, testing, adjustment, and calibration 
of machinery and equipment. It should be noted, however, that these 
activities are covered if they are part of or would be a logical part of 
the construction of a facility, or if construction type work, other than 
``incidental'' is involved.
    (4) Experimental development of equipment, processes, or devices 
including assembly, fitting, installation, testing, reworking, and 
disassembly. This refers to equipment, processes and devices which are 
assembled for the purpose of conducting a test or experiment. The design 
may be only conceptual in character, and professional personnel 
responsible for the experiment participate in the assembly. Specifically 
excluded from the category of experimental development are buildings and 
building utility services--as distinguished from temporary connections 
thereto. Also specifically excluded from this category is equipment to 
be used for continuous testing, e.g., a machine to be continuously used 
for testing the tensile strength of structural members.
    (5) Experimental work in connection with peaceful uses of nuclear 
energy. This refers to equipment, processes and devices which are 
assembled and/or set in place and interconnected for the purpose of 
conducting a test or experiment. The nature of the test or experiment is 
such that professional personnel responsible for the test or experiment 
and/or data to be derived therefrom necessarily must participate in the 
assembly and interconnections. Specifically excluded from experimental 
work are buildings, building utility services, structural changes, 
drilling, tunneling, excavation, and back-filling work which can be 
performed according to customary drawings and specifications, and 
utility services of modifications to utility services--as distinguished 
from temporary connections thereto. Work in this category may be 
performed in mines or in other locations specifically constructed for 
tests or experiments.
    (6) Emergency work to combat the effects of fire, flood, earthquake, 
equipment failure, accident or other casualties, and to restart the 
operational activity following the casualty. Work which is not directly 
related to restarting the activity or which involves rebuilding or 
replacement of structure or structural components or equipment is 
excluded from this category.
    (7) Decontamination including washing, scrubbing, and scraping to 
remove contamination; removal of contaminated soil or other material; 
and painting or other resurfacing, provided that such painting or 
resurfacing is an integral part of the decontamination activity and 
performed by the employees of the contractors performing the 
decontamination.
    (8) Burial of contaminated soil waste or contained liquid; however, 
initial preparatory work readying the burial ground for use (for 
example, any grading or excavating that is a part of initial site 
preparation, fencing, drilling wells for continued monitoring of 
contamination, construction of guard or other office space) is covered. 
Likewise, work subsequent to burial which involves the placement of 
concrete or other like activity is covered.
    (b) The classification of a contract as a contract for operational 
or maintenance activities does not necessarily mean that all work and 
activities at the contract location are classifiable as outside Davis-
Bacon Act coverage, since it may be necessary to separate out work which 
should be classified as covered. Therefore, the Heads of Contracting 
Activities shall establish and maintain controls for the careful 
scrutiny of proposed work assignments under such a contract to assure 
that:
    (1) Contractors whose contracts do not contemplate the performance 
of covered work with the contractor's own forces are neither asked nor 
authorized to perform work within the scope of the Davis-Bacon Act. If 
the actual work assignments do involve covered work, the contract should 
be modified to include applicable provisions of the Davis-Bacon Act.
    (2) Where covered work is performed by a contractor whose contract 
contains provisions required by the Davis-Bacon Act, such work is 
performed as required by law and the contract. After such contractor has 
been informed, as

[[Page 424]]

provided in paragraph (b)(3) of this section, that certain work is 
covered work, the Head of the Contracting Activity's responsibility to 
assure compliance is the same as it would be if the work were being 
performed under a separate construction contract.
    (3) Controls provided for above include consideration by the Head of 
the Contracting Activity and the contractor, before work is begun or 
contracted out, of the relation of the Davis-Bacon Act to (i) the annual 
programming of work, (ii) the contractor's work orders, and (iii) work 
contracted out in excess of $2,000. The Head of the Contracting Activity 
may, if he concludes that it is consistent with DOE's responsibilities 
as described in this section, prescribe from time to time classes of 
work as to which applicability or nonapplicability of the Davis-Bacon 
Act is clear, for which he will require no further DOE determination on 
coverage in advance of the work. For all work, controls to be 
established by the Head of the Contracting Activity should provide for 
notification to the contractor before work is begun as to whether such 
work is covered.
    The Head of the Contracting Activity is responsible for submitting 
to the Wage and Hours Division, Employment Standards Administration, 
Department of Labor, Washington, DC 20210, all DOE requests for project 
area or installation wage determinations, or individual determinations, 
or extensions or modification thereto. Requests for such determinations 
shall be made on Standard Form 308, at least 30 calendar days before 
they are required for use in advertising for bids or requests for 
proposals.
    (c) Experimental installations. Within DOE programs, a variety of 
experiments are conducted involving materials, fuels, coolants, 
processes equipment. Certain types of situations where tests and 
experiments have sometimes presented coverage questions are described 
below.
    (1) Set-ups of device and/or processes. The proving out of 
investigative findings and theories of a scientific and technical nature 
may require the set-up of various devices and/or processes at an early, 
pre-prototype stage of development. These may range from laboratory 
bench size to much larger set-ups. As a rule, these set-ups are made 
within established facilities (normally laboratories); required utility 
connections are made to services provided as a part of the basic 
facilities; and the activity as a whole falls within the functional 
purpose of the facility. Such set-ups are generally not covered. 
However, the erection of structures which are public works is covered if 
construction type work, other than an incidental amount is involved. 
Preparatory work for the set-up requiring structural changes or 
modifications of basic utility services--as distinguished from 
connections thereto--is covered. Following are illustrations of 
noncovered set-ups of devices and/or processes:
    (i) Assembly of piping and equipment within existing ``hot cell'' 
facilities for proving out a conceptual design of a chemical processing 
unit;
    (ii) Assembly of equipment, including adaptation and modification 
thereof, in existing ``hot cell'' facilities to prove out a conceptual 
design for remotely controlled machining equipment;
    (iii) Assembly of the first graphite pile in a stadium at Stagg 
Field in Chicago;
    (iv) Assembly of materials and equipment for particular aspects of 
the direct current thermonuclear experiments to explore feasibility and 
to study other ramifications of the concept of high energy injection and 
to collect data thereon.
    (2) Loops. Many experiments are carried on in equipment assemblies 
called loops in which liquids or gases are circulated under monitored 
and controlled conditions. For purposes of determining Davis-Bacon 
coverage, loops may be classed as loop facilities or as loop set-ups. 
Both of these classes of loops can include in-reactor loops and out-of-
reactor loops. In differentiating between clearly indentified loop set-
ups and loop facilities, an area exists in which there have been some 
questions of coverage, such as certain loops at the Material Test 
Reactor and at Engineering Test Reactor and the Idaho National 
Engineering Laboratory site. Upon clarification of this area, further 
illustrations will be added. In the meantime, the differentiation 
between loop set-ups and loop facilities must be

[[Page 425]]

made on a case-by-case basis, taking into account the total criteria set 
forth in this subpart.
    (i) Loop set-ups. The assembly, erection, modification, and 
disassembly of a loop set-up is noncovered. A noncontroversial example 
of a loop set-up is one which is assembled in a laboratory, e.g., Oak 
Ridge National Laboratory, Argonne National Laboratory, or Lawrence 
Livermore National Laboratory, for a particular test and thereafter 
disassembled. However, preparatory work for a loop set-up requiring 
structural changes or modifications of basic utility services--as 
distinguished from connections thereto--is covered, as are material and 
equipment that are installed for a loop set-up which is a permanent part 
of the facility or which is use for a succession of experimental 
programs.
    (ii) Loop facilities. A loop facility differs from a loop set-up in 
that it is of a more permanent character. It is usually, but not always, 
of greater size. It normally involves the building or modification of a 
structure. Sometimes it is installed as a part of construction of the 
facility. It may be designed for use in a succession of experimental 
programs over a longer period of time. Examples of loop facilities are 
the in-reactor ``K'' loops at Hanford and the large Aircraft Nuclear 
Propulsion loop at the Idaho National Engineering Laboratory site. The 
on-site assembly and erection of such loop facilities are covered. 
However, once a loop facility is completed and becomes operational, the 
criteria set forth above for operational and maintenance activities 
apply.
    (3) Reactor component experiments. Other experiments are carried on 
by insertion of experimental components within reactor systems without 
the use of a loop assembly. An example of reactor facilities erected for 
such experimental purposes are the special power excursion test reactors 
(SPETRs) at the National Reactor Test Site which are designed for 
studying reactor behavior and performance characteristics of certain 
reactor components. Such a facility may consist of a reactor vessel, 
pressurizing tank, coolant loops, pumps, heat exchangers, and other 
auxiliary equipment as needed. The facility also may include sufficient 
shielding to permit work on the reactor to proceed following a short 
period of power interruption, and buildings as needed to house the 
reactor and its auxiliary equipment. The erection and on-site assembly 
of such a reactor facility is covered, but the components whose 
characteristics are under study are excluded from coverage. To 
illustrate, one of the SPETRs planned for studies of nuclear reactor 
safety is designed to accommodate various internal fuel and control 
assemblies. The internal structure of the pressure vessel is designed so 
that cores of different shapes and sizes may be placed in the vessel for 
investigation, or the entire internal structure may be easily removed 
and replaced by a structure which will accept a different core design. 
Similarly, the control rod assembly is arranged to provide for 
flexibility in the removal of instrument leads and experimental 
assemblies from within the core.
    (4) Tests or experiments in peaceful uses of nuclear energy. These 
tests or experiments are varied in nature and some are only in a 
planning stage. They consist of one or more nuclear or nonnuclear 
detonations for the purposes of acquiring data. The data can include 
seismic effects, radiation effects, amount of heat generated, amount of 
material moved and so forth. Some of these tests are conducted in 
existing mines, while others are conducted in facilities specifically 
constructed for the tests or experiments. In general, all work which can 
be performed in accordance with customary drawings and specifications, 
as well as other work in connection with preparation of facilities is 
treated as covered work. Such work includes tunneling, drilling, 
excavation and back-filling, erection of buildings or other structures, 
and installation of utilities. The installation of the nonnuclear 
material or nuclear device to be detonated, and the instrumentation and 
connection between such material or device and the instrumentation are 
treated as noncovered work.
    (5) Tests or experiments in military uses of nuclear energy. As in 
970.2273(c)(4),

[[Page 426]]

these tests or experiments can be varied in nature. However, under this 
category it is intended to include only detonation of nonnuclear 
material or nuclear devices. The material or devices can be detonated 
either underground, at ground level, or above the ground. These tests or 
experiments have been conducted in, on, or in connection with facilities 
specifically constructed for such tests or experiments. As in tests or 
experiments in peaceful uses of nuclear energy, all work which can be 
performed in accord with customary drawings and specifications, as well 
as other work in connection with preparation of facilities are treated 
as covered work. Such work includes building towers or similar 
structures, tunneling, drilling, excavation and backfilling, erection of 
buildings or other structures, and installation of utilities. The 
installation of the nonnuclear material or nuclear devices and 
instrumentation are treated as noncovered work.
    (d) Construction site contiguous to an established manufacturing 
facility. As DOE-owned property sometimes embraces several thousand 
acres of real estate, a number of separate facilities may be located in 
areas contiguous to each other on the same property. These facilities 
may be built over a period of years, and established manufacturing 
activities may be regularly carried on at one site at the same time that 
construction of another facility is underway at another site. On 
occasion, the regular manufacturing activities of the operating 
contractor at the first site may include the manufacture, assembly, and 
reconditioning of components and equipment which in other industries 
would normally be done in established commercial plants. While the 
manufacture of components and equipment in the manufacturing plant is 
noncovered, the installation of any such manufactured items on a 
construction job is covered.
[49 FR 12063, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 9110, Feb. 25, 1994; 62 FR 2312, Jan. 16, 1997]



970.2274  Whistleblower protection of contractor employees.



970.2274-1  General.

    (a) This section implements the DOE Contractor Employee Protection 
Program as set forth at 10 CFR part 708. Part 708 establishes criteria 
and procedures for the investigation, hearing, and review of allegations 
from DOE contractor employees of employer reprisal resulting from 
employee disclosure of information to DOE, to members of Congress, or to 
the contractor; employee participation in proceedings before Congress or 
pursuant to this rule; or employee refusal to engage in illegal or 
dangerous activities, when such disclosure, participation, or refusal 
pertains to employer practices which the employee believes to be unsafe; 
to violate laws, rules, or regulations; or to involve fraud, 
mismanagement, waste, or abuse. Part 708 is applicable to employees of:
    (1) DOE management and operating contractors,
    (2) Other contractors performing work on-site at DOE-owned or -
leased facilities, and
    (3) Subcontractors under paragraphs (a)(1) and (a)(2) of this 
section performing work on-site at DOE-owned or -leased facilities.
    (b) DOE will direct contractors found to have discriminated against 
an employee in reprisal for such disclosure, participation, or refusal 
to provide relief to the complainant.
    (c) 10 CFR 708.4 essentially defines the term ``work performed on-
site'' to mean work performed within the boundaries of a DOE-owned or -
leased facility. However, work will not be considered to be performed 
``on-site'' when the only work performed within the boundaries of a DOE 
facility is ancillary to the primary purpose of the contract (e.g., the 
on-site delivery of goods produced off-site).
    (d) 10 CFR 708.12(b) provides that for the purposes of the Contract 
Disputes Act (41 U.S.C. 605 and 606) a final decision issued pursuant to 
10 CFR part 708 shall not be considered to be a claim by the Government 
against a contractor or a decision by the contracting officer

[[Page 427]]

subject to appeal. However, a contractor's disagreement, and refusal to 
comply, with a final decision could result in a contracting officer's 
decision to disallow certain costs or to terminate the contract for 
default. In such case, the contractor could file a claim under the 
Disputes clause of the contract regarding the cost disallowance or 
contract termination.
[57 FR 57639, Dec. 4, 1992]



970.2274-2  Clause.

    The contracting officer shall insert the clause at 970.5204-59, 
Whistleblower Protection for Contractor Employees, in management and 
operating contracts.
[57 FR 57640, Dec. 4, 1992; 58 FR 39679, July 26, 1993]



970.2275  Overtime management.



970.2275-1  General.

    Contracting officers shall ensure that management and operating 
contractors manage overtime cost effectively and use overtime only when 
necessary to ensure performance of work under the contract.
[62 FR 34864, June 27, 1997]



970.2275-2  Contract clause.

    The contracting officer shall insert the clause at 48 CFR (DEAR) 
970.5204-80, Overtime Management, in management and operating contracts.
[62 FR 34864, June 27, 1997]



  Subpart 970.23--Environmental, Conservation, and Occupational Safety 
                                Programs



970.2303  Hazardous materials identification and material safety.



970.2303-1  General.

    (a) The Department of Energy regulates the nuclear safety of its 
major facilities under its own statutory authority derived from the 
Atomic Energy Act and other legislation. The Department also regulates, 
under certain specific conditions, the use by its contractors of 
radioactive materials and ionizing radiation producing machines.
    (b) The inclusion of environmental, safety and health clauses in DOE 
contracts shall be made by the contracting officer in consultation with 
appropriate environmental, safety and health program management 
personnel.



970.2303-2  Clauses.

    (a) When work under management and operating contracts and 
subcontracts thereunder is to be performed at a facility where DOE will 
exercise its statutory authority to enforce occupational safety and 
health standards applicable to the working conditions of the contractor 
and subcontractor employees at such facility, the clause at 970.5204-2 
shall be used in such contract or subcontract and made applicable to the 
work if conditions (a)(1) through (3), are satisfied:
    (1) DOE work is segregated from the contractor's or subcontractor's 
other work;
    (2) The operation is of sufficient size to support its own safety 
and health services; and
    (3) The facility is government-owned, or leased by or for the 
account of the government.
    (b) The clause set forth in 952.223-72 shall be included in those 
contracts or subcontracts for, and be made applicable to, work to be 
performed at a facility where DOE does not elect to assert its statutory 
authority to enforce occupational safety and health standards applicable 
to the working conditions of contractor and subcontractor employees, but 
does need to enforce radiological safety and health standards pursuant 
to provisions of the contract or subcontract rather than by reliance 
upon Nuclear Regulatory Commission licensing requirements (including 
agreements with states under section 274 of the Atomic Energy Act).
[49 FR 12063, Mar. 28, 1984; 49 FR 38952, Oct. 2, 1984, as amended at 59 
FR 5531, Feb. 7, 1994; 59 FR 9110, Feb. 25, 1994; 62 FR 34864, June 27, 
1997]

[[Page 428]]



970.2304  Use of recovered/recycled materials.



970.2304-1  General.

    The policy for the acquisition and use of environmentally preferable 
products and services is described at 48 CFR (DEAR) subpart 923.4.
[60 FR 47492, Sept. 13, 1995]



970.2304-2  Contract clause.

    The contracting officer shall insert the clause at 48 CFR (DEAR) 
970.5204-39, Acquisition and Use of Environmentally Preferable Products 
and Services, in management and operating contracts.
[60 FR 47492, Sept. 13, 1995]



970.2305  Workplace substance abuse programs--management and operating contracts.



970.2305-1  General.

    (a) The Department of Energy (DOE), as part of its overall 
responsibilities to protect the environment, maintain public health and 
safety, and safeguard the national security, has established policies, 
criteria, and procedures for management and operating contractors to 
develop and implement programs that help maintain a workplace free from 
the use of illegal drugs.
    (b) Regulations concerning DOE's management and operating contractor 
workplace substance abuse programs are promulgated at 10 CFR part 707, 
Workplace Substance Abuse Programs at DOE Sites.
[57 FR 32676, July 22, 1992]



970.2305-2  Applicability.

    (a) All management and operating contracts awarded under the 
authority of the Atomic Energy Act of 1954, as amended, are required to 
implement the policies, criteria, and procedures of 10 CFR part 707, 
Workplace Substance Abuse Programs at DOE Sites.
    (b) Except as otherwise provided for in this subpart, management and 
operating contracts subject to the requirements of 10 CFR part 707 and 
this subpart shall not be subject to FAR 23.5, Drug Free Workplace.
[57 FR 32676, July 22, 1992]



970.2305-3  Definitions.

    Terms and words relating to DOE's Workplace Substance Abuse 
Programs, as used in this section, have the same meanings assigned to 
such terms and words in 10 CFR part 707.
[57 FR 32676, July 22, 1992]



970.2305-4  Solicitation provision and contract clause.

    (a) The contracting officer shall insert the provision at 48 CFR 
970.5204-57, Agreement Regarding Workplace Substance Abuse Programs at 
DOE Sites, in solicitations for the management and operation of DOE-
owned or -controlled sites operated under the authotiry of the Atomic 
Energy Act of 1954, as amended.
    (b) The contracting officer shall insert the clause at 970.5204-58, 
Workplace Substance Abuse Programs at DOE Sites, in contracts for the 
management and operation of DOE-owned or -controlled sites operated 
under the authority of the Atomic Energy Act of 1954, as amended.
[57 FR 32676, July 22, 1992, as amended at 62 FR 42075, Aug. 5, 1997]



970.2305-5  Suspension of payments, termination of contract, and debarment and suspension actions.

    (a) The contracting officer shall comply with the procedures of FAR 
23.506 regarding the suspension of contract payments, the termination of 
the contract for default, and the debarment and suspension of a 
contractor relative to failure to comply with 970.5204-58, Workplace 
Substance Abuse Programs at DOE Sites.
    (b) For purposes of 10 CFR part 707, the specific causes for 
suspension of contract payments, termination of the contract for 
default, and debarment and suspension of the contractor are:
    (1) The contractor fails to either comply with the requirements of 
10 CFR part 707 or perform in a manner consistent with its approved 
program;
    (2) The contractor has failed to comply with the terms of the 
provision at 48 CFR 970.5204-57;
    (3) Such a number of contractor employees having been convicted of 
violations of criminal drug statutes for violations occurring on the 
DOE-owned or

[[Page 429]]

-controlled site, as to indicate that the contractor has failed to make 
a good faith effort to provide a drug free workplace; or,
    (4) The offeror has submitted a false certification in response to 
the provision at 970.5204-57, Certification Regarding Workplace 
Substance Abuse Programs at DOE Sites.
[57 FR 32677, July 22, 1992, as amended at 62 FR 42075, Aug. 5, 1997]



                        Subpart 970.25 [Reserved]



              Subpart 970.26--Other Socioeconomic Programs



970.2601  Implementation of Section 3021 of the Energy Policy Act of 1992.

    (a) The goal requirements of Section 3021 of the Energy Policy Act 
of 1992, and the attendant reporting requirements shall be included in 
the subcontracting plan for the management and operating contract and 
shall apply to the annual dollar obligations specifically provided to 
the Management and Operating contractor for competitively awarded 
subcontracts that fulfill Energy Policy Act requirements. See 970.7104-
12(f).
    (b) Department of Energy policy recognizes that full utilization of 
the talents and capabilities of a diverse work force is critical to the 
achievement of its mission. The principal goals of this policy are to 
foster and enhance partnerships with small, small disadvantaged, woman-
owned small businesses, and educational institutions; to match 
capabilities with existing opportunities; to track small, small 
disadvantaged, woman-owned small business, and educational activity; and 
to develop innovative strategies to increase opportunities.
[60 FR 22302, May 5, 1995, as amended at 62 FR 34864, June 27, 1997]



970.2602-1  Implementation of Section 3161 of the National Defense Authorization Act for Fiscal Year 1993.

    (a) Consistent with the objectives of Section 3161 of the National 
Defense Authorization Act for Fiscal Year 1993, 42 U.S.C. 7474h, in 
instances where the Department of Energy has determined that a change in 
work force at a DOE Defense Nuclear Facility is necessary, DOE 
contractors and subcontractors at DOE Defense Nuclear Facilities shall 
accomplish work force restructuring or displacement so as to mitigate 
social and economic impacts and in a manner consistent with any DOE work 
force restructuring plan in effect for the facility or site. In all 
cases, mitigation shall include the requirement for hiring preferences 
for employees whose positions have been terminated (except for 
termination for cause) as a result of changes to the work force at the 
facility due to restructuring accomplished under the requirements of 
Section 3161. Where applicable, contractors may take additional actions 
to mitigate consistent with the Department's Workforce Restructuring 
Plan for the facility or site.
    (b) The requirements set forth in 48 CFR (DEAR) 926.71, 
Implementation of Section 3161 of the National Defense Authorization Act 
for Fiscal Year 1993, for contractors and subcontractors to provide a 
hiring preference for employees under Department of Energy contracts 
whose employment in positions at a Department of Energy Defense Nuclear 
Facility is terminated (except for a termination for cause) applies to 
management and operating contracts.
[62 FR 34864, June 27, 1997]



970.2602-2  Contract clause.

    The contracting officer shall insert the clause at 48 CFR (DEAR) 
970.5204-77, Workforce Restructuring Under Section 3161 of the National 
Defense Authorization Act for Fiscal Year 1993, in contracts for the 
management and operation of Department of Energy Defense Nuclear 
Facilities and, as appropriate, in other contracts that include site 
management responsibilities at a Department of Energy Defense Nuclear 
Facility.
[62 FR 34864, June 27, 1997]



              Subpart 970.27--Patents, Data, and Copyrights



970.2701  General.

    This subpart applies to negotiation of patent rights and rights in 
technical data provisions for the Department of

[[Page 430]]

Energy contracts for the management and operation of its research and 
development and production facilities.
[60 FR 11822, Mar. 2, 1995]



970.2702  Patent rights.

    (a) Whenever a contract has as a purpose, the design, construction, 
or operation of a Government-owned research, development, demonstration 
or production facility, it is necessary that the Government be accorded 
certain rights with respect to further use of the facility by or on 
behalf of the Government upon termination of the contract, including the 
right to make, use, transfer, or otherwise dispose of all articles, 
materials, products, or processes embodying inventions or discoveries 
used or embodied in the facility regardless of whether or not conceived 
or first actually reduced to practice under or in the course of such a 
contract. Thus, both versions of the patent rights clause for management 
and operating contracts contain a facilities license.
    (b) In the case of contractors operating and managing DOE research 
and development or production facilities, that are not the beneficiaries 
of Public Law 96-517, the Department is statutorily obligated to take 
title to inventions conceived or first actually reduced to practice in 
the performance of the contracts. Here, as in all other circumstances in 
which the Department takes title to inventions by statute, the 
contractors may request a waiver at the time of contracting for a class 
of inventions or during contract performance for identified inventions. 
DOE includes the considerations at 42 U.S.C. 5908 in its determination 
as to whether to approve the request.
    (c) While no contractor that manages and operates a DOE research and 
development or production facility is a small business, several have 
historically been nonprofit organizations. As such, they are the 
beneficiaries of the Bayh-Dole Act (35 U.S.C. 200 et seq., as amended) 
and, therefore, receive the right to retain title to inventions 
conceived or first actually reduced to practice in the performance of 
their contracts with the Department, except in areas of technology 
covered by Exceptional Circumstances Determinations made by DOE or of 
nuclear weapons and naval nuclear propulsion. In these latter two areas, 
the contractor may request that the Department waive its title and, 
therefore, subject to the exceptions identified below, may be granted 
title to inventions conceived or first actually reduced to practice in 
the performance of its contract with the Department.
    (d) DOE has exercised statutory authority granted under 35 U.S.C. 
202(a)(ii) and 202(a)(iv). In accordance with 35 U.S.C. 202(a)(ii), DOE 
has issued several Exceptional Circumstances Determinations pursuant to 
which DOE nonprofit management and operating contractors have no right 
to elect title to inventions conceived or first actually reduced to 
practice in the course of or under their contracts within covered areas 
of technology. However, those contractors may be given some lesser 
property right in an invention within limits set by DOE in a particular 
Exceptional Circumstances Determination so that the contractor can 
effectively assist with a mission of DOE, such as technology transfer. 
As new technologies evolve, DOE may issue additional Exceptional 
Circumstances Determinations, as appropriate.
    (e) In accordance with 35 U.S.C. 202(a)(iv), the Department of 
Energy has exempted its weapons related and naval nuclear propulsion 
programs from the broad Bayh-Dole right of its nonprofit management and 
operating contractors to elect title to inventions conceived or first 
actually reduced to practice in the course of or under their contracts. 
The effect of this exemption is that, if the contractors want to acquire 
title, they must request title to covered inventions. DOE may then grant 
the request subject to a case-by-case determination that the contractor 
has met all procedural requirements unilaterally set by DOE to insure 
that all national security concerns of DOE relating to the contractor's 
use of an invention in either of these two areas for commercialization 
have been met.
[60 FR 11822, Mar. 2, 1995]



970.2703  Technology transfer.

    The National Competitiveness Technology Transfer Act of 1989 (NCTTA) 
(Pub. L. 101-189) established technology transfer as a mission for 
Government-

[[Page 431]]

owned, contractor-operated laboratories, including weapons production 
facilities, and authorizes those laboratories to negotiate and award 
cooperative research and development agreements with public and private 
entities for purposes of conducting research and development and 
transferring technology to the private sector. In implementing the 
NCTTA, DOE has negotiated technology transfer clauses with the 
contractors managing and operating its laboratories. Those technology 
transfer clauses must be read in concert with the patent rights clause 
required by this subpart. Thus, each management and operating contractor 
holds title to subject inventions for the benefit of the laboratory or 
facility being managed and operated by that contractor.
[60 FR 11823, Mar. 2, 1995]



970.2704  Patent clauses.

    (a) Contracting officers shall insert the clause at 970.5204-71 in 
all management and operating contracts with nonprofit organizations.
    (b) Contracting officers shall insert the clause at 970.5204-72 in 
all management and operating contracts with profit-making entities.
[60 FR 11823, Mar. 2, 1995]



970.2705  Rights in technical data--general.

    (a) A management and operating contractor's obligations for 
protection of information and data received from DOE and other 
contractors or subcontractors, and for the contractor's private use of 
contract data first produced in the performance of the contract, are set 
forth in paragraph (b)(2) of each Rights in Technical Data clause in 
952.227. That subparagraph provides that the contractor may, subject to 
patent, security, or other provisions of the contract, use for its 
private purposes, contract data it first produces in the performance of 
the contract, provided that the contractor has met its data requirements 
(e.g., delivery of data in the form of progress or status reports 
specified to be delivered) as of the date of private use of such data. 
It is not necessary that a ``Final Report'' be submitted in order to 
privately use data if all required progress and interim reports and 
other technical data then due have been delivered. Paragraph (b)(2) of 
each Rights in Technical Data clause in 952.227 further provides that 
technical or other data received by the contractor in the performance of 
the contract must be held in confidence by the contractor in accordance 
with restrictions accompanying the data.
    (b) Contractors should be aware that technical information which is 
reported to DOE by DOE contractors may be disseminated by DOE to others, 
subject to the restrictions included in the ``Rights to Technical Data'' 
clause.
    (c) Employees of contractors operating DOE facilities may not be 
used to assist in the preparation of a proposal or bid for the 
performance of private commercial services similar or related to those 
being performed under the DOE contract unless such employee has been 
separated, with DOE approval, from performance of work under the DOE 
contract for such period as the Head of the Contracting Activity or 
designee shall direct consistent with the purpose of this section.
    (d) Contractors operating DOE facilities and performing services as 
a part of their contract work for other Government agencies or private 
organizations should not be permitted to utilize information which is 
furnished by such customers for their own private activities unless it 
is generally available to others, or unless the customer authorizes such 
use.
[60 FR 11823, Mar. 2, 1995]



970.2706  Rights in technical data--procedures.

    (a) General. It is essential that DOE maintain continuity in its 
programs which are implemented by contracts for the operation of 
Government-owned facilities. Contract data first produced or 
specifically used in the performance of such contracts must be 
considered as integral to and remaining with the facility or plant after 
termination of such contracts and thus available to DOE and its future 
contractors for the continued use of the facility or plant. However, it 
is recognized that these contracts by their nature cannot always be 
subject to one set of prescribed

[[Page 432]]

contract provisions which will always apply. Accordingly, the Rights in 
Technical Data-Facility clause set forth in 952.227-78 is to be used as 
a basic or minimal clause which may be modified or expanded with the 
concurrence of Patent Counsel to meet particular contract situations.
    (b) Whenever a contract has as a purpose the operation of a 
Government-owned research or production facility, the clause set forth 
at 952.227-78 shall normally be included in the contract. Inasmuch as 
this clause secures to the Government ownership, access to, and, if 
requested, delivery of all technical data first produced in the 
performance of the contract and access to and delivery of technical data 
which are specifically used in the performance of the contract, there is 
no need to include the Additional Technical Data Requirements Clause of 
952.227-73.
    (c) Subcontracting. Unless otherwise directed by the contracting 
officer, the contractor shall be required to follow the policy and 
procedures of 927.402-1, 927.402-2, and 927.402-3 and shall employ the 
provisions of the Additional Technical Data Requirements clause of 
952.227-73 and the Rights in Technical Data (Long Form) clause of 
952.227-75, where appropriate, except in subcontracts for the design of 
special production plants or facilities or specially designed equipment 
for facilities or plants, in which instances contractors shall include 
the provisions of the Rights in Technical Data--Facility clause of 
952.227-78.
    (d) Optional clause--Limited rights in proprietary data. In 
contracts where it is determined that delivery of proprietary data is 
necessary with limited rights in the Government, the Rights in Technical 
Data clause of this section shall be supplemented by the additional 
paragraph (e), set forth in 952.227-79. Paragraph (e) provides that 
technical data may be specified in the contract as being excluded from 
the delivery requirements thereof. Alternatively, paragraph (e) may be 
limited or made applicable to only those classes of proprietary data 
determined as being necessary for delivery with limited rights. In 
addition, when furnishing proprietary data with the limited rights 
legend, paragraphs (a), (b) and (c) of 952.227-79 may be modified as 
follows. When proprietary data is to be furnished only for evaluation, 
paragraph (a) of the limited rights legend shall be used, and paragraphs 
(b) and (c), if otherwise inapplicable, may be deleted. When there is a 
programmatic requirement that proprietary data be disclosed to other DOE 
contractors only for information or use in connection with work 
performed under their contracts, paragraph (b) of the limited rights 
legend shall be used, and paragraphs (a) and (c) may be deleted if 
otherwise inapplicable. In either of the foregoing examples, the 
contractor may, if it can show the possibility of a conflict of interest 
because of disclosure of such data to certain contractors or evaluators, 
exclude contractors or evaluators from paragraph (a) or (b). If the data 
is required solely for emergency repair or overhaul, paragraph (c) of 
the limited rights legend shall be retained, and paragraphs (a) and (b) 
may, unless otherwise applicable, be deleted. In the event that it is 
determined that all of the paragraphs (a), (b) and (c) of the limited 
rights legend are to be deleted, the word ``none'' shall be inserted in 
the legend after the colon (:).
    (e) For contracts involving access to certain categories of DOE-
owned restricted data, as set forth in 10 CFR part 725, see 927.402-
1(h).
[60 FR 11823, Mar. 2, 1995]



                   Subpart 970.28--Bonds and Insurance



970.2830  Contract clause.

     The contracting officer shall insert the clause at 48 CFR (DEAR) 
970.5204-31, Insurance--Litigation and Claims, in management and 
operating contracts. Paragraphs (h)(3) and (j)(2) apply to a nonprofit 
contractor only to the extent specifically provided in the individual 
contract.
[62 FR 34864, June 27, 1997]



970.2870  Indemnification.

    (a) Section 170d. of the Atomic Energy Act of 1954, as amended, 
requires DOE to enter into agreements of indemnity with contractors 
whose work involves the risk of public liability for

[[Page 433]]

the occurrence of a nuclear incident or precautionary evacuation.
    (b) Details of such indemnification are discussed in more detail at 
950.70.
    (c) The clause at 970.5204-6 shall be included in all management and 
operating contracts involving the risk of public liability for the 
occurrence of a nuclear incident or precautionary evacuation arising out 
of or in connection with the contract work, including such events caused 
by a product delivered to a DOE-owned, facility for use by DOE or its 
contractors. The clause at 970.5204-6 also shall be included in any 
management and operating contract for the design of a DOE facility, the 
construction or operation of which may involve the risk of public 
liability for a nuclear incident or a precautionary evacuation.
    (d) However, the clause at 952.250-70 shall not be included in 
contracts in which the contractor is subject to Nuclear Regulatory 
Commission (NRC) financial protection requirements under section 170b. 
of the Act or NRC agreements of indemnification under section 170 c. or 
k. of the Act for activities to be performed under the contract.
    (e) DOE contractors with whom statutory nuclear hazards indemnity 
agreements under the authority of section 170d. of the Atomic Energy Act 
of 1954, as amended, are executed will not normally be required or 
permitted to furnish financial protection by purchase of insurance to 
cover public liability for nuclear incidents. However, if authorized by 
the DOE headquarters office having responsibility for contractor 
casualty insurance programs, DOE contractors may be (1) permitted to 
furnish financial protection to themselves or (2) permitted to continue 
to carry such insurance at cost to the Government if they currently 
maintain insurance for such liability.
[56 FR 57830, Nov. 14, 1991]



                          Subpart 970.29--Taxes



970.2901  Exemptions from Federal excise taxes.

    (a) The exemption respecting taxes on communication services or 
facilities has been held to extend to such services when furnished to 
DOE management and operating contractors who pay for such services or 
facilities from advances made to them by DOE under their contracts.
    (b) Where it is considered that a request for an additional 
exemption in the performance of a management and operating contract 
would be justified, a recommendation that such a request be made should 
be forwarded to the Chief Financial Officer, Headquarters.
    (c) Where tax exemption certificates are required in connection with 
the foregoing taxes, the Head of the Contracting Activity will supply 
standard Government forms (SF 1094, U.S. Tax Exemption Certificate) on 
request.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.2902  State and local taxes.

    It is DOE policy to secure those immunities or exemptions from state 
and local taxes to which it is entitled under the Federal Constitution 
or state laws. In carrying out this policy, the Heads of Contracting 
Activities shall:
    (a) Take all necessary steps to preclude payment of any taxes for 
which any of the foregoing immunities or exemptions are available. 
Advice of Counsel should be sought as to the availability of such 
immunities or exemptions;
    (b) Acquire directly and furnish to contractors as Government 
furnished property, equipment, material, or services when, in the 
opinion of the Head of the Contracting Activity:
    (1) Such direct acquisition will result in substantial savings to 
the Government, taking into consideration any additional administrative 
costs;
    (2) Such direct acquisition will not have a substantial adverse 
effect on the relationship between DOE and its contractor; and
    (3) Such direct acquisition will not have a substantial adverse 
effect on the DOE program or schedules.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.2903  Contract clause.

    Contracting officers shall include the clause Taxes, at 970.5204-23, 
in management and operating contracts.
[62 FR 2312, Jan. 16, 1997]

[[Page 434]]



                Subpart 970.30--Cost Accounting Standards



970.3001  General.



970.3001-1  Applicability.

    The provisions of (FAR) 48 CFR part 30 and (FAR Appendix B) 48 CFR 
9904.414 shall be followed for management and operating contracts.
[60 FR 30006, June 7, 1995]



970.3001-2  Limitations.

    Cost of money as an element of the cost of facilities capital (CAS 
414) and as an element of the cost of capital assets under construction 
(CAS 417) is not recognized as an allowable cost under contracts subject 
to 48 CFR part 970 (See 970.3102-3).
[60 FR 30006, June 7, 1995]



         Subpart 970.31--Contract Cost Principles and Procedures



970.3100  Scope and applicability of subpart.

    The cost principles, procedures and general policy for the 
determination of reimbursable costs applicable to the administration of 
management and operating contracts are set for in this subpart. The 
terms ``reimbursement'' and ``reimbursable'' are used interchangeably in 
relation to ``allowable costs'' as a matter of editorial convenience. No 
``reimbursement'' is actually involved in those situations where the 
cost-type contractor makes payments for ``allowable cost'' from 
Government funds advanced to him by the DOE.



970.3100-1  Definitions.

    Off-site work is contract required work (under a contract covered by 
FAR Subpart 17.6) performed in contractor-owned facilities, such as a 
central or branch office.
    On-site work (under a contract covered by FAR Subpart 17.6) is work 
performed at the Government-site.
    Direct costs of a management and operating contract are defined as 
follows:
    (a) With respect to on-site work, ``direct costs'' technically 
include all performance costs; that is, such costs are identified 
specifically for, or account of, the contract. However, in some 
circumstances it may be desirable or necessary because of the 
requirements of the contract to distinguish between direct and indirect 
types of costs. ``Direct costs,'' when the foregoing circumstances 
apply, are those which are identified as having been incurred 
specifically for, or on account of a designated cost objective, such as 
a particular product (or groups of similar products), work order, job, 
project, program or contract. Materials, labors or expenses which relate 
specifically and solely to the manufacture of a particular product or to 
the performance of a distinct job or work are broad examples of direct 
costs. Direct costs are not limited to items incorporated in an end 
product.
    (b) With respect to ``off-site'' work, ``direct costs'' are as 
defined in FAR 31.202 and discussed in other sections of this subpart.
    ``Indirect costs'' of a management and operating contract are 
defined as follows:
    (a) With respect to ``on-site'' work, when it is desirable or 
necessary to distinguish them from direct costs, ``indirect costs'' are 
those items of material, labor, and expenses not directly identified 
with a single final cost accumulation point, but identified with 
applicability to two or more objectives or with at least one 
intermediate cost objective.
    (b) With respect to ``off-site'' work, ``indirect cost'' are as 
defined in FAR 31.203 and discussed in other sections of this subpart.



970.3100-2  Responsibilities.

    (a) The Procurement Executive is responsible for developing and 
revising the policy and procedures for the determination of allowable 
costs reimbursable under a management and operating contract, and for 
seeing that they are properly coordinated with other Headquarters' 
offices having joint interests.
    (b) The Head of the Contracting Activity is responsible for 
following the policy, principles and standards set forth herein in 
establishing the compensation provisions of contracts and subcontracts 
and for submission of deviations for Headquarters consideration.

[[Page 435]]



970.3100-3  Deviation.

    Deviations from the policy and principles set forth in this subpart 
shall not be made unless such action is authorized by the Procurement 
Executive, on the basis of a written justification stating clearly the 
special circumstances involved. Where appropriate, any approved 
deviation shall be reflected in the compensation provisions of the 
contract.



970.3101  General policy.

    The cost policies of the DOE regarding management and operating 
contracting are as discussed in this section:



970.3101-1  Actual cost basis.

    (a) DOE shall reimburse its contractors for costs incurred in the 
performance of a management and operating contract in accordance with 
its terms and the provisions of this subpart. Such costs are those 
allowable costs provided for in the contract to the extent that they are 
necessary or incident, and either directly attributable or equitably 
allocable to the work under the contract. This broad expression of the 
DOE's cost-reimbursement policy is further developed and elaborated upon 
throughout this subpart.
    (b) DOE uses retrospective or after-the-fact determination, usually 
called the actual cost basis, to establish the amount reimbursable. This 
general policy precludes the use of predetermined fixed percentage rates 
except for provisional payments.
    (c) When a fixed compensation for any otherwise allowable cost is 
separately negotiated, the items of such costs covered by the fixed 
amount shall be identified with maximum clarity and set forth in an 
appropriate appendix to the contract as an amount otherwise excludable 
from other reimbursable costs (this is done in order to distinguish 
between those allowable costs subject to reimbursement and those costs 
which are covered by the negotiated fixed amount).
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.3101-2  Direct and indirect costs.

    (a) Direct costs identified specifically with a management and 
operating contract are direct cost of performing that contract and are 
to be charged directly thereto. All costs specifically identified with 
other final cost objectives of the management and operating contractor 
are direct cost of those cost objectives and are not to be charged to 
the contract directly or indirectly. For reasons of practicality, any 
direct cost of minor dollar amount may be treated as an indirect cost if 
the accounting treatment--
    (1) Is consistently applied; and
    (2) Produces substantially the same results as treating the cost as 
a direct cost.
    (b) Indirect cost are not subject to treatment as a direct cost and 
thus directly chargeable to a contract. After direct costs have been 
determined and charged directly to the contract or other work, indirect 
costs are those remaining to be allocated from an appropriate indirect 
cost accumulation account. The following principles and procedures shall 
apply to indirect costs to the extent that they are incurred under 
management and operating contracts.
    (1) Indirect costs to the extent required to be or otherwise 
incurred in the accounting system of the operating contractor shall be 
accumulated by logical cost groupings with due consideration of the 
reasons for incurring such costs. Each grouping should be determined so 
as to permit distribution of the grouping on the basis of the benefits 
accruing to the cost objectives to which it is to be allocated. 
Generally, overhead and general and administrative (G&A) expenses are 
separately grouped. Similarly, the particular case may require 
subdivision of these groupings; e.g., building occupancy costs might be 
separable from those of personnel administration within a specific 
overhead group such as manufacturing overhead. This necessitates 
selecting a distribution base common to all cost objectives to which the 
grouping is to be allocated. The base should be selected so as to permit 
allocation of the grouping on the basis of the benefits accruing to the 
cost objectives. The number and composition of cost

[[Page 436]]

groupings should be governed by practical considerations and should not 
unduly complicate the allocation.
    (2) Once an appropriate base for distributing indirect costs has 
been accepted, it shall not be fragmented by removing individual 
elements. For example, when a cost input base is used for the 
distribution of G&A costs, all items that would properly be part of the 
costs input base, whether allowable or unallowable, shall be included in 
the base and bear their pro rata share or G&A costs.
    (3) The method of allocating indirect costs shall be in accordance 
with generally accepted accounting principles which are consistently 
applied.
    (4) A base period for allocating indirect costs is the cost 
accounting period during which such costs are incurred and accumulated 
for distribution to work performed in that period.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.3101-3  General basis for reimbursement of costs.

    (a) The total reimbursable cost of a DOE management and operating 
contract is the sum of the allowable direct costs necessary or incident 
to the performance of the contract, plus any properly allocable portion 
of allowable indirect costs, (including corporate or home office G&A 
expense, or branch office indirect expenses), if any, less applicable 
income and other credits. In determining allowability and 
reimbursability of costs, the following shall be considered:
    (1) Allowability and reasonableness in accordance with FAR 31.201-
2(d) and 31.201-3;
    (2) Allocability of a cost to management and operating contract. A 
cost is allocable if it is assignable or chargeable for work and 
performance of the contract in accordance with the relative benefits 
received or other equitable relationship;
    (3) Application of generally accepted accounting principles and 
practices appropriate to identifying and measuring costs of performing 
the contract in accordance with this subpart;
    (4) All exclusions of and limitations of types and amounts of items 
of cost set forth in the contract;
    (5) Approvals by the contracting officer required under the contract 
terms; and
    (6) Cost accounting standards if applicable.
[49 FR 12063, Mar. 28, 1984, as amended at 62 FR 34865, June 27, 1997]



970.3101-4  Cost determination based on audit.

    The amount reimbursable under management and operating contracts 
shall be determined in accordance with the principles set forth in this 
subpart and in accordance with the terms of the respective contract on 
the basis of audit. In the event that the contractual terms differ, or 
are inconsistent with (see 970.3100-3 for approval of deviations) the 
principles stated herein, the contractual terms control. It is expected 
however, contractual terms to be based on the principles therein. The 
audit may be performed directly by DOE (or by the cognizant Federal 
agency pursuant to arrangements made by the DOE).
[49 FR 12063, Mar. 28, 1984, as amended at 53 FR 24231, June 27, 1988]



970.3101-5  Contractor's system of accounting.

    (a) Careful DOE study of a management and operating contractor's 
usual accounting procedures shall be made prior to arriving at an 
understanding with the contractor as to the accounting system to be 
employed by the contractor during the period of contract performance.
    (b) A contractor's customary accounting practices are usually 
accepted for management and operating contracts if they conform to 
generally accepted accounting principles, produce equitable results, are 
consistently applied, are not in conflict with the provisions of this 
subpart, are conducive to accurate costing of the contract work, and 
produce reports required by the DOE.



970.3101-6  Advance understandings on particular cost items.

    (a) It is important that agreement between DOE and its management 
and operating contractors be reached in advance of the incurrence of 
costs in categories where reasonableness as to

[[Page 437]]

amounts or allocability to the management and operating contract are 
difficult to determine in order to avoid possible subsequent 
disallowance or dispute. Any such agreement should be incorporated in 
the contract. But the absence of such agreement on any element of cost 
will not, in itself, serve to make the element either allowable or 
unallowable. Examples of costs on which advance agreements may be 
particularly important are:
    (1) Deferred maintenance costs;
    (2) Precontract costs;
    (3) Professional or technical consulting services;
    (4) Reconversion costs;
    (5) Research and development costs;
    (6) Royalties;
    (7) Selling and distribution costs;
    (8) Unemployment insurance experience ratings;
    (9) Employee compensation, including amounts of money or percentage 
of payment authorized to be expended annually for groups of employees 
for all types of wage and salary increases, travel, relocation expenses 
and other personnel costs.
    (10) Lobbying costs;
    (11) Public relations and advertising; and
    (12) Travel and relocation costs as related to special or mass 
personnel movements and as related to travel via contractor-owned 
leased, or chartered aircraft.
    (b) DOE generally utilizes two basic methods of achieving and 
recording understandings with contractors as to the allowability of 
employee compensation, travel, relocation, and other personnel costs: 
(1) Negotiation of a personnel appendix to the contract, which sets 
forth the policies, programs, and schedules which are accepted as the 
basis for determining the allowability of costs; or (2) reviewing and 
reaching agreements on established policies, programs, and schedules 
(and any changes thereto during the contract term) applicable to 
contractor's private operations which are acceptable for contract work 
and which will be consistently followed throughout the contractor's 
organization. A personnel appendix to the contract setting forth advance 
understandings covering compensation for personal services shall be 
utilized in management and operating contracts (as defined in FAR 
17.601) when one or more of the following circumstances exist: when 
policies, programs, and schedules are established specifically for 
contract work; when the contractor's work is predominantly or 
exclusively made up of negotiated Government contract work; when 
contract work is so different from the organization's private work that 
existing established policies, programs, and schedules cannot reasonably 
be extended to and consistently applied on contract work; or, when 
established policies, programs, and schedules proposed for contract work 
are not sufficiently definitive to permit a clear advance mutual 
understanding of allowable costs and to provide a basis for audit. The 
Head of the Contracting Activity is authorized to select the alternative 
method of achieving and recording advance understanding that they find 
most appropriate, after considering the facts of the particular contract 
situation. As used in this paragraph:
    (c) With regard to the costs at (a)(9) of this section:
    (1) Compensation for personal services includes wages and salaries, 
bonuses and incentives, premium payments, pay for time not worked, and 
supplementary compensation and benefits, such as pension and retirement, 
group insurance, severance pay plans, and other forms of compensation 
covered by 970.3102-2.
    (2) Employee travel costs include transportation expenses incurred 
while on official business, within the U.S. or outside the U.S. as 
necessary. Travel of executive officers is covered in 970.3102-17. 
Contractor travel policies must be acceptable to the Department, and 
result in reasonable cost necessary for contract performance. To avoid 
disputes and to clearly state the treatment that applies to travel cost, 
advance understandings should be reached with the management and 
operating contractor. They should be sufficiently definitive to evidence 
the contractor's responsibility to minimize costs consistent with 
contract performance. The allowability to certain travel costs, such as 
air travel, are specifically limited by Department policy. For example, 
the added cost of first

[[Page 438]]

class air travel is prohibited as a reimbursable cost, except under 
stringent conditions, which must be justified in writing. Contractually 
enforceable understandings concerning the allowability and reimbursement 
of other potentially significant travel costs (such as the use of 
Government-furnished automobiles or Government-contract provided rental 
automobiles) should be reached with the contractor. A reasonable basis 
for such understandings is the Federal travel policy applicable to 
Government and directly paid contractor employees.
    (3) Other personnel costs include:
    (i) Morale, health, welfare, food service and dormitory costs 
covered in 970.3102-5;
    (ii) Training and education costs covered in 970.5204-13 and 
970.5204-14;
    (iii) Relocation costs for relocating employees as discussed in 
970.3102-16; and special or mass personnel movement covered in 970.3102-
2(i).
[49 FR 12063, Mar. 28, 1984, as amended at 52 FR 1607, Jan. 14, 1987]



970.3102  Application of cost principles.

    The incurred costs of performing management and operating contracts 
shall be reimbursed to the extent they are reasonable, allocable, and 
determined to be allowable under the provisions of this subpart and the 
terms of the contract. The DOE principles on allowability of selected 
items or classification of cost or situations expected to be associated 
with the performance of contract work as stated in this section.



970.3102-1  General and administrative expenses.

    (a) For on-site work, the DOE considers that its fee allowance for 
management and operating contracts provides for the recognition of 
appropriate compensation for home or corporate office general and 
administrative expenses incurred in the general management of the 
contractor's business as a whole.
    (b) The above policy is intended to preclude the payment of general 
and administrative expenses merely because they are incurred or 
accounted for at or by a contractor's home or corporate office and not 
the operating site. The DOE recognizes some benefit of such cost to the 
DOE program. The basis of recognition through fee allowance is 
associated with the difficulty of determining and assessing the dollar 
value of such expenses that might be applicable to or have benefit to a 
management and operating contract. Conventional allocation techniques; 
i.e., total operating costs, labor dollars or hours, etc., are generally 
not considered appropriate because they normally distribute such 
expenses over a base representative of contractor investment (in terms 
of its own resources, including labor, material, overhead, etc.). 
Contractor investments and home office contributions are minimal under 
DOE's operating and management contracts in as much as they are totally 
financed and supported by DOE advance payments under the letter-of-
credit method and by DOE's provision of government-owned and project-
exclusive facilities, property, and other needed resources.
    (c) Notwithstanding the concept in (a) above, it is recognized that 
from time to time the fee amounts established for a management and 
operating contract, to meet the purpose cited in 970.1509-1 and 
consideration of the factors in 970.1509-4, may be considered 
insufficient to adequately recognize a contractor's general and 
administrative expenses incurred in general management and 
administration of the contractor's business as a whole and which appear 
to have a directly benefiting relationship to the DOE program. Such 
recognitions may be the basis of requesting fee amounts in excess of the 
limitations set forth in 970.1509-5 or alternatively, in any particular 
case, the contractor may be compensated on the basis of cost in 
accordance with 970.3101-1 if the Head of the Contracting Activity or 
other approving contract official authorizes or approves the procedure 
and a fair and reasonable amount can be agreed upon. Such amount shall 
normally be in addition to the applicable fee amounts.
    (d) The DOE allows company general and administrative expenses under 
off-site architect-engineer, supply and research contracts with 
commercial contractors performing the work in their own facilities. 
Contractor's general and

[[Page 439]]

administrative expenses, may, however, be included for reimbursement 
under such DOE off-site architect-engineer, supply and research 
contracts, only to the extent that they are established, after careful 
examination, to be allowable in nature an properly allocable to the 
work. Work performed in a contractor's own facilities under a management 
and operating or construction contract may likewise be allowed to bear 
the properly allocable portion of allowable company general and 
administrative expense.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.3102-2  Compensation for personal services.

    (a) General. Compensation for personal services includes all 
remuneration paid currently or accrued, in whatever form and whether 
paid immediately or deferred, for services rendered by employees to the 
contractor during the period of contract performance (except as 
otherwise provided for severance pay costs in paragraph (b)(4)(i) of 
this section and for pension cost in paragraph (b)(1) of this section). 
It includes, but is not limited to, salaries; wages; directors' and 
executive committee members' fees; bonuses (including stock bonuses); 
incentive awards; employee stock options, stock appreciation rights, and 
stock ownership plans; employee insurance; fringe benefits; 
contributions to pension, annuity, and management employee incentive 
compensation plans; and allowances for off-site pay, incentive pay, 
location allowances, hardship pay, severance pay, and cost of living 
differential.
    (b) Allowability. Reimbursable costs for compensation for personal 
services are to be set forth in a personnel appendix in the contract as 
discussed at 970.3101-6. This personnel appendix shall be negotiated 
using the principles and policies of this 970.3102-2, and other 
pertinent parts of the DEAR. However, costs that are unallowable 
pursuant to other paragraphs of 970.3102 or contract terms shall not be 
allowable under this 970.3102-2 on the basis they constitute 
compensation for personnel services. Costs of compensation for personal 
services are reimbursable to the extent that:
    (1) The compensation is for personal services work performed by the 
employee in the current year and must not represent a retroactive 
adjustment of prior year's salaries or wages (but see 970.3102-2 (i), 
(j), (l), (m), and (n));
    (2) The compensation in total is reasonable for the work performed; 
however, specific restrictions on individual compensation elements must 
be observed where they are prescribed;
    (3) The compensation is based upon and conforms to the terms and 
conditions of the contractor's established compensation plan or practice 
followed so consistently as to imply, in effect, an agreement to make 
the payment;
    (4) Any approvals prescribed by this 970.3102-2 are obtained. No 
assumption of allowability will exist where the contractor introduces 
major revisions of existing compensation plans or new plans and the 
contractor--
    (i) Has not notified the cognizant contracting officer of the 
changes either before their implementation, or within a reasonable 
period after their implementation, and
    (ii) Has not provided the Government, either before implementation 
or within a reasonable period after it, an opportunity to review the 
allowability of the changes.
    (5) Costs that are unallowable under the contract terms or other 
paragraphs of this 970.3102 shall not be allowable under this 970.3102-2 
solely on the basis that they constitute compensation for personal 
services.
    (c) Reasonableness. Subject to 970.3102-2(d) of this section 
compensation for personal services will be considered reasonable if the 
total compensation conforms generally to compensation paid by other 
firms of the same size, in the same industry, or in the same geographic 
area for similar services or work performed. This does not preclude the 
Government from challenging the reasonableness of an individual element 
of compensation where costs are excessive in comparison with 
compensation paid by other firms of the same size, same industry, or in 
the same geographic area for similar services. In administering this 
principle, it is recognized that not

[[Page 440]]

every compensation case need be subjected in detail to the above tests. 
The tests need be applied only when a general review reveals amounts or 
types of compensation that appear unreasonable or unjustified. In 
questionable cases, the contractor has responsibility to support the 
reasonableness of compensation in relation to the effort performed. 
Compensation costs under certain conditions give rise to the need for 
special consideration. Among such conditions are the following:
    (1) Compensation to (i) owners of closely held corporations, 
partners, sole proprietors, or members of their immediate families, or 
(ii) persons who are contractually committed to acquire a substantial 
financial interest in the contractor's enterprise. Determination should 
be made that salaries are reasonable for the personal services rendered 
rather than being a distribution of profits. Compensation in lieu of 
salary for services rendered by partners and sole proprietors will be 
allowed to the extent that it is reasonable and does not constitute a 
distribution of profits. For closely held corporations, compensation 
costs covered by this subparagraph shall not be recognized in amounts 
exceeding those costs that are deductible as compensation under the 
Internal Revenue Code and its regulations.
    (2) Any change in a contractor's compensation policy that results in 
a substantial increase in the contractor's level of compensation, 
particularly when it was concurrent with an increase in the ratio of 
Government contracts to other business, or any change in the treatment 
of allowability of specific types of compensation due to changes in the 
treatment of allowability of specific types of compensation due to 
changes in Government policy. No presumption of reasonableness will 
exist where major revisions of existing compensation plans or new plans 
are introduced by the contractor; and the contractor--
    (i) Has not notified the cognizant contracting officer of the change 
either before their implementation or within a reasonable period after 
their implementation; and
    (ii) Has not provided the Government, either before implementation 
or within a reasonable period after it, an opportunity to review the 
reasonableness of the changes.
    (3) The contractor's business is such that its compensation levels 
are not subject to the restraints that normally occur in the conduct of 
competitive business.
    (4) The contractor incurs costs for compensation in excess of the 
amounts which are deductible under the Internal Revenue Code and its 
regulations.
    (d) DOE review and approval of compensation paid individual 
employees. In determining the reasonableness of compensation, the 
compensation of each individual contractor employee normally need not be 
subjected to review and approval. Generally, the compensation paid 
individual employees should be left to the judgment of contractors 
subject to the limitations of DOE-approved compensation policies, 
programs, classification systems, and schedules, and amounts of money 
authorized for wage and salary increases for groups of employees. 
However, all compensation due an individual of $80,000 or more shall 
require the contracting officer's or designee's review and approval. In 
addition, it will often be necessary that employee compensation be 
subjected to review and approval on an individual basis at a level below 
$80,000, when the contracting officer finds it appropriate for the 
particular situation. The contract shall specifically provide for the 
approval by the contracting officer of the cost of compensating an 
individual contractor employee above the level determined by the 
contracting officer, if a total of 50 percent or more of such 
compensation is reimbursed under DOE cost-type contracts. For purposes 
of determining the level for individual review and approval, total 
compensation as used in this paragraph includes only the employee's 
salary and bonus or incentive compensation. As in the case of other 
personnel and compensation costs, it is intended that contracting 
officer review and approval of individual compensation normally will be 
prior to incurrence of costs.
    (e) Labor-management agreements. Notwithstanding any other DOE 
requirements, costs of compensation are not

[[Page 441]]

allowable to the extent that they result from provisions of labor-
management agreements that, as applied to work in performing Government 
contracts, are determined to be unreasonable because they are either 
unwarranted by the character and circumstances of the work or 
discriminatory against the Government. The application of the provisions 
of a labor-management agreement designed to apply to a given set of 
circumstances and conditions of employment (e.g., work involving 
extremely hazardous activities or work not requiring recurrent use of 
overtime) is unwarranted when applied to a Government contract involving 
significantly different circumstances and conditions of employment 
(e.g., work involving less hazardous activities or work continually 
requiring use of overtime). It is discriminatory against the Government 
if it results in employee compensation (in whatever form or name) in 
excess of that being paid for similar non-Government work under 
comparable circumstances. Disallowance of costs will not be made under 
this paragraph (e) unless--
    (1) The contractor has been permitted an opportunity to justify the 
costs; and
    (2) Due consideration has been given to whether unusual conditions 
pertain to Government contract work, imposing burdens, hardships, or 
hazards on the contractor's employees, for which compensation that might 
otherwise appear unreasonable is required to attract and hold necessary 
personnel.
    (f) Salaries and wages. Salaries and wages for current services 
include gross compensation paid to employees in the form of cash, stock 
(see paragraph (h)(2) of this section regarding valuation), products, or 
services, and are allowable.
    (g) Domestic and foreign differential pay. (1) When personal 
services are performed in a foreign country, compensation may also 
include a differential that may properly consider all expenses 
associated with foreign employment such as housing, cost of living 
adjustments, transportation, bonuses, additional Federal, state, local 
or foreign income taxes resulting from foreign assignment, and other 
related expenses.
    (h) Bonuses and incentive compensation. Incentive compensation and 
cash bonuses based on production, cost reduction or efficient 
performance, suggestion awards, and safety awards are to be treated as 
allowable, to the extent that the contractor's overall compensation plan 
is determined to be reasonable and such costs are paid or accrued, 
pursuant to an agreement entered into in good faith between the 
contractor and the employees before the services were rendered, or 
pursuant to an established plan followed by the contractor so 
consistently as to imply, in effect, an agreement to make such payment 
(see 970.3101-6). In determining reasonableness, it will be necessary to 
take into account, not only bonuses and incentive compensation payments 
charged directly to the contract, but also payments charged indirectly 
to the contract through overhead. Bonuses, awards, and incentive 
compensation, when any of them are deferred, are to be treated as 
allowable to the extent provided in paragraph (m) of this section.
    (1) Bonuses and incentive compensation paid to employees other than 
those whose pay is directly reimbursed will not be made allowable in on-
site construction and management and operating contracts, where home 
office general and administrative expense is unallowable.
    (2) When the costs of bonuses and incentive compensation are paid in 
the stock of the contractor or of an affiliate, the following additional 
restrictions apply:
    (i) Valuation placed on the stock shall be the fair market value on 
the measurement date (i.e., the first date the number of shares awarded 
is known) determined upon the most objective basis available; and
    (ii) Accruals for the cost of stock before issuing the stock to the 
employees shall be subject to adjustment according to the possibilities 
that the employees will not receive the stock and that their interest in 
the accruals will be forfeited.
    (3) When the bonus and incentive compensation payments are deferred,

[[Page 442]]

the costs are subject to the requirements of paragraph (h)(1) of this 
section and of paragraph (m) of this section.
    (i) Severance pay. (1) Severance pay, also commonly referred to as 
dismissal wages, is a payment in addition to regular salaries and wages 
by contractors to workers whose employment is being involuntarily 
terminated. Payments for early retirement incentive plans are covered in 
paragraph (l)(6) of this section.
    (2) Severance pay to be allowable must meet the general allowability 
criteria in paragraph (i)(2)(i) of this section, and, depending upon 
whether the severance is normal or abnormal, criteria in paragraph 
(i)(2)(ii) of this section for normal severance pay or paragraph 
(i)(2)(iii) of this section for abnormal severance pay also apply.
    (i) Severance pay is allowable only to the extent that, in each 
case, it is required by (A) law, (B) employer-employee agreement, (C) 
established policy that constitutes, in effect, an implied agreement on 
the contractor's part, or (D) circumstances of the particular 
employment. Payments made in the event of employment with a replacement 
contractor where continuity of employment with credit for prior length 
of service is preserved under substantially equal conditions of 
employment, or continued employment by the contractor at another 
facility, subsidiary, affiliate, or parent company of the contractor are 
not severance pay and are unallowable.
    (ii) Actual normal turnover severance payments shall be allocated to 
all work performed in the contractor's plant, or where the contractor 
provides for accrual of pay for normal severances, that method will be 
acceptable if the amount of the accrual is reasonable in light of 
payments actually made for normal severances over a representative past 
period and if amounts accrued are allocated to all work performed at the 
facility.
    (iii) Abnormal or mass severance pay is of such a conjectural nature 
that measurement of costs by means of an accrual will not achieve equity 
to both parties. Thus, accruals for this purpose are not allowable. 
However, the Government recognizes its obligation to participate, to the 
extent of its fair share, in any specific payment. Thus, allowability 
will be considered on a case-by-case basis.
    (3) Subject to paragraph (a) of this section, the following 
standards apply in determining allowability of costs for severance pay 
plans of management and operating contractors:
    (i) Payments should be made only upon involuntary termination by 
reduction in force (RIF) of an employee which results in a permanent 
separation from the employment of the contractor. However, payments may 
also be made upon voluntary separation of an employee within a RIF 
grouping, but not otherwise scheduled for termination, which thereby 
eliminates the need for terminating another employee involuntarily.
    (ii) Payments should be not provided for in the event of temporary 
layoffs; employment or offer of employment with a replacement contractor 
(employer) where continuity of employment with credit for prior length 
of service is preserved under substantially equal conditions of 
employment; early or normal retirement; or continued employment by the 
contractor at another facility, subsidiary, affiliate, or parent company 
of the contractor. Contractor employees should not have the option of 
refusing employment to receive severance pay.
    (j) Backpay--(1) Backpay resulting from violations of Federal labor 
laws or the Civil Rights Act of 1964. Backpay may result from a 
negotiated settlement, order, or court decree that resolves a violation 
of Federal labor laws or the Civil Rights Act of 1964. Such backpay 
falls into two categories: one requiring the contractor to pay employees 
additional compensation for work performed for which they were 
underpaid, and the other resulting from other violations, such as when 
the employee was improperly discharged, discriminated against, or other 
circumstances for which the backpay was not additional compensation for 
work performed. Backpay resulting from underpaid work is compensation 
for the work performed and is allowable. All other backpay resulting 
from willful violation of Federal labor laws or the Civil Rights Act of 
1964 is unallowable.

[[Page 443]]

    (2) Other backpay. Backpay may also result from payments to union 
employees (union and non-union) for the difference in their past and 
current wage rates for working without a contract or labor agreement 
during labor management negotiations. Such backpay is allowable. Backpay 
to nonunion employee based upon results of union agreement negotiations 
is allowable only if (i) a formal agreement or understanding exists 
between management and the employees concerning these payments, or (ii) 
an established policy or practice exists and is followed by the 
contractor so consistently as to imply, in effect, an agreement to make 
such payment.
    (k) Stock options, stock appreciation rights, and phantom stock 
plans. (1) The cost of stock options awarded to employees to purchase 
stock of the contractor or of an affiliate will be treated as deferred 
compensation and must comply with the requirements of paragraph (m) of 
this section and with the allowability criteria contained in paragraph 
(k)(2) of this section. The allowable cost of stock appreciation rights, 
whether offered separately or combined with stock options, will be 
determined in the same manner as stock options.
    (2) The allowable costs of stock options and stock appreciation 
rights will be limited to the difference between the option price or 
stock-appreciation-right price and the market price of the stock on the 
measurement date (i.e., the first date on which both the number of 
shares and the option or stock-appreciation-right price are known). 
Accordingly, when the option or stock-appreciation-right price is equal 
to or greater than the market price on the measurement date, then no 
costs are allowed for contract costing purposes.
    (3) In phantom-stock-type plans, contractors assign or attribute 
contingent shares of stock to employees as if the employees own the 
stock, even though the employees neither purchase the stock nor receive 
title to it. Under these plans, an employee's account may be increased 
by the equivalent of dividends issued and any appreciation in the market 
price of the stock over the price of the stock on the measurement date 
(i.e., the first date the number of shares awarded is known). Such 
increases in employee accounts for dividend equivalents and market price 
appreciation are unallowable.
    (l) Pension costs. (1) A pension plan is a deferred compensation 
plan that is established and maintained by one or more employers to 
provide systematically for paying benefits to plan participants after 
their retirement, provided that the benefits are paid for life or are 
payable for life at the option of the employee. Additional benefits such 
as permanent and total disability and death payments and survivorship 
payments to beneficiaries of deceased employees may be treated as 
pension costs, provided the benefits are an integral part of the pension 
plan and meet all the criteria pertaining to pension costs.
    (2) Pension plans are normally segregated into two types of plans: 
defined benefit or defined contribution pension plans. Except as 
provided by other DOE directives, the cost of all defined benefit 
pension plans shall be measured, allocated, and accounted for in 
compliance with the provisions of CAS 412, Composition and Measurement 
of Pension Costs, and CAS 413, Adjustment and Allocation of Pension 
Cost. The costs of all defined contribution pension plans shall be 
measured, allocated, and accounted for in accordance with the provisions 
of CAS 412. Pension costs are allowable subject to directives issued by 
the Office of Contractor Human Resource Management, Headquarters, the 
referenced standards and the cost limitations and exclusions set forth 
below in this paragraph and in paragraphs (l) (3), (4), (5), (6), and 
(7) below.
    (i) To be allowable in the current year, pension costs must be 
funded by the time set for filing the Federal income tax return or any 
extension thereof. Pension costs assigned to the current year, but not 
funded by the tax return time, shall not be allowable in any subsequent 
year.
    (ii) Pension payments must be reasonable in amount and be paid 
pursuant to (A) an agreement entered into in good faith between the 
contractor and employees before the work or services are performed and 
(B) the terms and conditions of the established plan. The cost of 
changes in pension plans which

[[Page 444]]

are discriminatory to the Government or are not intended to be applied 
consistently for all employees under similar circumstances in the future 
are not allowable.
    (iii) Except as provided for early retirement benefits in paragraph 
(l)(6) below, one-time-only pension supplements not available to all 
participants of the basic plan are not allowable as pension costs unless 
the supplemental benefits represent a separate pension plan and the 
benefits are payable for life at the option of the employee.
    (iv) Increases in payments to previously retired plan participants 
covering cost-of-living adjustments are allowable if paid in accordance 
with a policy or practice consistently followed.
    (3) Defined benefit pension plans. This paragraph covers pension 
plans in which the benefits to be paid or the basis for determining such 
benefits are established in advance and the contributions are intended 
to provide the stated benefits. The cost limitations and exclusions 
pertaining to defined benefit plans are as follows:
    (i) Normal costs of pension plans not funded in the year incurred, 
and all other components of pension costs (see CAS 412.40(a)(1)) 
assignable to the current accounting period but not funded during it, 
shall not be allowable in subsequent years (except that a payment made 
to a fund by the time set for filing the Federal income tax return or 
any extension thereof is considered to have been made during such 
taxable year). However, any part of a pension cost that is computed for 
a cost accounting period that is deferred pursuant to a waiver granted 
under the provisions of the Employee's Retirement Income Security Act of 
1974 (ERISA) (see CAS 412.50(c)(3)), will be allowable in those future 
accounting periods in which the funding does occur. The allowability of 
these deferred contributions will be limited to the amounts that would 
have been allowed had the funding occurred in the year the costs would 
have been assigned except for the waiver.
    (ii) Any amount paid or funded before the time it becomes assignable 
and allowable shall be applied to future years, in order of time, as if 
actually paid and deductible in those years. The interest earned on such 
premature funding, based on the valuation rate of return, may be 
excluded from future years' computations of pension costs in accordance 
with CAS 412.50(a)(7).
    (iii) Increased pension costs caused by delay in funding beyond 30 
days after each quarter of the year to which they are assignable are 
unallowable. If a composite rate is used for allocating pension costs 
between the segments of a company and if, because of differences in the 
timing of the funding by the segments, an inequity exists, allowable 
pension costs for each segment will be limited to that particular 
segment's calculation of pension costs as provided for in CAS 
413.50(c)(5). Determination of unallowable costs shall be made in 
accordance with the actuarial method used in calculating pension costs.
    (iv) Allowability of the cost of indemnifying the Pension Benefit 
Guaranty Corporation (PBGC) under ERISA section 4062 or 4064 arising 
from terminating an employee deferred compensation plan will be 
considered on a case-by-case basis; provided that if insurance was 
required by the PBGC under ERISA section 4023, it was so obtained and 
the indemnification payment is not recoverable under the insurance. 
Consideration under the foregoing circumstances will be primarily for 
the purpose of appraising the extent to which the indemnification 
payment is allocable to Government work. If a beneficial or other 
equitable relationship exists, the Government will participate in the 
indemnification payment to the extent of its fair share.
    (4) Defined contribution pension plans. This paragraph covers those 
pension plans in which the contributions to be made are established in 
advance and the level of benefits is determined by the contributions 
made. It also covers profit sharing, savings plans, and other such plans 
provided the plans fall within the definition of a pension plan in 
paragraph (l)(1) of this section.
    (i) The pension cost assignable to a cost accounting period is the 
net contribution required to be made for that period after taking into 
account dividends and other credits, where applicable. However, any 
portion of pension

[[Page 445]]

cost computed for a cost accounting period that is deferred pursuant to 
a waiver granted under the provisions of ERISA (see CAS 412.50(c)(3)) 
will be allowable in those future accounting periods when the funding 
does occur. The allowability of these deferred contributions will be 
limited to the amounts that would have been allowed had the funding been 
made in the year the costs would have been assigned except for the 
waiver.
    (ii) Any amount paid or funded to the trust before the time it 
becomes assignable and allowable shall be applied to future years, in 
order of time, as if actually paid and deductible in such years.
    (iii) The provisions of paragraph (l)(3)(vi) of this section 
concerning payments to PBGC apply to defined contribution plans.
    (5) Pension plans using pay-as-you-go methods. A pension plan using 
pay-as-you-go methods is a plan in which the contractor recognizes 
pension cost only when benefits are paid to retired employees or their 
beneficiaries. Regardless of whether the payment of pension benefits 
contribution can or cannot be compelled, allowable costs for these types 
of plans shall not exceed an amount computed as follows:
    (i) Compute, by using an actuarial cost method, the plan's actuarial 
liability for benefits earned by plan participants. This entire 
liability is always unfunded for a pay-as-you-go plan.
    (ii) Compute a level amount which, including an interest equivalent, 
would amortize the unfunded actuarial liability over a period of no less 
than 10 or more than 40 years from the inception of the liability.
    (iii) Compute, by using an actuarial cost method, a normal cost for 
the period.
    (iv) The sum of paragraphs (l)(5) (i), (ii), and (iii) of this 
section represents the amount of pension costs assignable to the current 
period. This amount, however, is limited to the amount paid in the year.
    (v) For purposes of determining contract cost where a pay-as-you-go 
plan is initiated as either a supplemental plan or an additional but 
separate plan to a basic funded plan, the plans will be treated as one 
plan; e.g., the actuarial cost method, past service amortization period, 
etc., of the basic plan will be used on the supplemental or additional 
pay-as-you-go plan in determining the proper costs assignable to the 
current period. Any costs in excess of those determined by using the 
actuarial cost method and assumptions of the basic plan are unallowable. 
However, where assumption for salary progressions, mortality rates of 
the participants, and so forth are significantly different, the 
assumptions used for the basic and supplemental plan may be different.
    (vi) The requirements of paragraphs (l)(3) (i) through (iv) of this 
section are also applicable to pay-as-you-go plans.
    (6) Early retirement incentive plans. An early retirement incentive 
plan is a plan under which employees receive a bonus or incentive, over 
and above the requirement of the basic pension plan, to retire early. 
These plans normally are not applicable to all participants of the basic 
plan and do not represent life income settlements, and as such would not 
qualify as pension costs. However, for contract costing purposes, early 
retirement incentive payments are allowable subject to pension criteria 
contained in paragraphs (l)(3)(i) through (iv) provided--
    (i) The costs are accounted for and allocated in accordance with the 
contractor's system of accounting for pension costs (see paragraph 
(l)(5)(v) of this section for supplemental pension benefits);
    (ii) The payments are made in accordance with the terms and 
conditions of the contractor's plan;
    (iii) The plan is applied only to active employees. The cost of 
extending the plan to employees who retired or were terminated before 
the adoption of the plan is unallowable; and
    (iv) The total of the incentive payments to any employee may not 
exceed the amount of the employee's annual salary for the previous 
fiscal year before the employee's retirement.
    (7) Employee stock ownership plans (ESOP). (i) An ESOP is an 
individual stock bonus plan designed specifically to invest in the stock 
of the employer corporation. The contractor's contributions to an 
Employee Stock Ownership Trust (ESOT) may be in the form of

[[Page 446]]

cash, stock, or property. Costs of ESOP's are allowable subject to the 
following conditions:
    (A) Contributions by the contractor in any one year may not exceed 
15 percent (25 percent when a money purchase plan is included) of 
salaries and wages of employees participating in the plan in any 
particular year.
    (B) The contribution rate (ratio of contribution to salaries and 
wages of participating employees) may not exceed the last approved 
contribution rate except when approved by the contracting officer based 
upon justification provided by the contractor. When no contribution was 
made in the previous year for an existing ESOP, or when a new ESOP is 
first established, and the contractor proposes to make a contribution in 
the current year, the contribution rate shall be subject to the 
contracting officer's approval.
    (C) When a plan or agreement exists wherein the liability for the 
contribution can be compelled for a specific year, the expense 
associated with that liability is assignable only to that period. Any 
portion of the contribution not funded by the time set for filing of the 
Federal income tax return for that year or any extension thereof shall 
not be allowable in subsequent years.
    (D) When a plan or agreement exists wherein the liability for the 
contribution cannot be compelled, the amount contributed for any year is 
assignable to that year provided the amount is funded by the time set 
for filing of the Federal income tax return for that year.
    (E) When the contribution is in the form of stock, the value of the 
stock contribution shall be limited to the fair market value of the 
stock on the date that title is effectively transferred to the trust. 
Cash contributions shall be allowable only when the contractor furnishes 
evidence satisfactory to the contracting officer demonstrating that 
stock purchases by the ESOT are or will be at a fair market price; e.g., 
makes arrangements with the trust permitting the contracting officer to 
examine purchases of stock by the trust to determine that prices paid 
are at fair market value. When excessive prices are paid, the amount of 
the excess will be credited to the same indirect cost pools that were 
charged for the ESOP contributions in the year in which the stock 
purchase occurs. However, when the trust purchases the stock with 
borrowed funds which will be repaid over a period of years by cash 
contributions from the contractor to the trust, the excess price over 
fair market value shall be credited to the indirect cost pools pro rata 
over the period of years during which the contractor contributes the 
cash used by the trust to repay the loan. When the fair market value of 
unissued stock or stock of a closely held corporation is not readily 
determinable, the valuation will be made on a case-by-case basis taking 
into consideration the guidelines for valuation used by the IRS.
    (ii) Amounts contributed to an ESOP arising from either (A) an 
additional investment tax credit (see 1975 Tax Reduction Act); or (B) a 
payroll-based tax credit (see Economic Recovery Tax Act of 1981) are 
unallowable.
    (iii) The requirements of paragraphs (l)(3)(ii) of this section are 
applicable to Employee Stock Ownership Plans.
    (m) Deferred compensation. (1) Deferred compensation is an award 
given by an employer to compensate an employee in a future cost 
accounting period or periods for services rendered in one or more cost 
accounting periods before the date of receipt of compensation by the 
employee. Deferred compensation does not include the amount of year-end 
accruals for salaries, wages, or bonuses that are paid within a 
reasonable period of time after the end of a cost accounting period. 
Subject to 970.3102-2(a), deferred awards are allowable when they are 
based on current or future services. Awards made in periods subsequent 
to the period when the work being remunerated was performed are not 
allowable.
    (2) The costs of deferred awards shall be measured, allocated, and 
accounted for in compliance with the provisions of CAS 415, Accounting 
for the Cost of Deferred Compensation.
    (3) Deferred compensation payments to employees under awards made 
before the effective date of CAS 415 are allowable to the extent they 
would have been allowable under prior acquisition regulations.

[[Page 447]]

    (n) Fringe benefits. Fringe benefits are allowances and services 
provided by the contractor to its employees, as compensation, in 
addition to regular wages and salaries. Subject to the determination 
that total compensation is reasonable in accordance with this 970.3102-
2, costs of fringe benefits such as pay for vacations, holidays, sick 
leave, military leave, employee insurance, pension, retirement plans, 
and supplemental unemployment benefit plans are to be treated as 
allowable, provided such fringe benefits meet the following conditions;
    (1) The benefits contribute to the performance of contract work and 
are appropriate for reimbursement from public funds;
    (2) Such benefit plans as exist in the contractor's private 
operations that are inconsistent with DOE published requirements are 
appropriately modified or disallowed;
    (3) Employee benefit plans especially established to meet the 
particular needs of the contract are in conformity with published DOE 
policy and standards;
    (4) Appropriate controls under the contract are established to 
assure that employees on contract work are treated no more or no less 
favorably than employees in the contractor's private operation, except 
to the extent that paragraphs (n)(2) and (3) of this section apply;
    (5) To the fullest extent possible, definite limitations or terminal 
points are established for each of the various benefit plans, so that 
DOE's full liability with respect thereto is established under the 
contract; and
    (6) DOE has access to all information necessary to complete 
understanding of the means of computing or determining the cost of the 
benefits afforded contract employees and their dependents under the 
benefit plans.
    (o) Training and education expenses. See 970.5204-13 and 970.5204-
14.
[49 FR 12063, Mar. 28, 1984, as amended at 49 FR 26744, June 29, 1984; 
49 FR 32953, Oct. 2, 1984; 55 FR 5462, Feb. 15, 1990; 56 FR 41965, Aug. 
26, 1991; 58 FR 36365, July 7, 1993; 59 FR 9110, Feb. 25, 1994]



970.3102-3  Cost of money.

    Cost of money as an element of the (a) cost of facilities capital 
(CAS 414) and (b) cost of capital assets under construction (CAS 417) is 
not an allowable cost under DOE management and operating contracts. 
Under the provisions of CAS 414 and CAS 417, cost of money is an imputed 
cost applicable to contractor owned and financed tangible capital assets 
employed in contract performance or being constructed, fabricated, or 
developed for ultimate employment in contract performance. Cost of money 
is not applicable to DOE management and operating contracts since the 
Government provides for assets used, or under construction for use in 
performance of its contracts (such as through Government furnished or 
contractor-acquired Government property contract provisions and/or 
through granting cash advances, including letters-of-credit.)



970.3102-4  Depreciation.

    (a) Depreciation is allowable subject to the following:
    (1) The charge represents normal depreciation on a contractor's 
plant and equipment used in performance of management and operating 
work.
    (2) The charge to current operations is a distribution of the cost 
of acquisition of a tangible capital asset, less estimated residual 
value, over the estimated useful life of the asset, in a systematic and 
logical manner.
    (3) Any generally accepted accounting method consistently applied to 
assets concerned having the approval of the Internal Revenue Service for 
Federal income tax purposes, if subject to the Internal Revenue Code of 
1954, as amended, may be used including:
    (i) The straight-line method;
    (ii) The declining balance method, using a rate not exceeding twice 
the rate which would have been used had the annual allowance been 
computed under the method described in paragraph (a)(3)(i) of this 
section;
    (iii) The sum-of-the-years digits method;
    (iv) Any other consistent method productive of an annual allowance 
which, when added to all allowances for the period commencing with the 
use of the property and including the current

[[Page 448]]

year, does not, during the first two-thirds of the useful life of the 
property, exceed the total of such allowances which would have been 
used, had such allowances been computed under the method described in 
paragraph (a)(3)(ii) of this section.
    (4) If a nonprofit or tax-exempt organization, the method shall be 
such that it could have had the approval of the Internal Revenue 
Service, had the organization been subject to the Internal Revenue Code 
of 1954, as amended.
    (5) The contractor must use the same approved method of depreciation 
for costing its contract work as for costing its other work at the same 
facility.
    (6) The method of depreciation shall produce equitable and 
reasonable results.
    (b) Depreciation of the following is unallowable:
    (1) Idle or excess facilities (machinery and equipment), other than 
reasonable standby facilities;
    (2) Assets fully amortized or depreciated on the contractor's books;
    (3) Unrealized appreciation of values of assets; and
    (4) Accelerated amortization under Certificates of Necessity or 
other system in excess of normal depreciation, as computed under 
paragraph (a) of this section.
    (c) In entering into contracts involving the use of ``special 
facilities'' under section 161 of the Atomic Energy Act of 1954, as 
amended (section 7 of Pub. L. 85-681 approved Aug. 19, 1958), the 
percentage of the total cost of such special facilities devoted to 
contract performance and chargeable to the DOE should not exceed the 
ratio between the period of contract deliveries and the anticipated 
useful life of such facilities.



970.3102-5  Employee morale, health, welfare, food service, and dormitory costs.

    (a) Employee morale, health, and welfare activities are those 
services or benefits provided by the contractor to its employees to 
improve working conditions, employer-employee relations, employee 
morale, and employee performance. These activities include such items as 
house or employee publications, health or first-aid clinics, recreation, 
employee counseling services and, for the purpose of this section, food 
service and dormitory costs. However, these activities do not include, 
and should be differentiated from compensation for personal services as 
defined in 970.3102-2. Food and dormitory services include operating or 
furnishing facilities for cafeterias, dining rooms, canteens, lunch 
wagons, vending machines, living accommodations, or similar types of 
services for the contractor's employees at or near the contractor's 
facilities or site of the contract work.
    (b) Except as limited by paragraph (c) of this section, the 
aggregate of costs incurred on account of all activities mentioned in 
paragraph (a) of this section, less income generated by all such 
activities, is allowable to the extent that the net aggregate cost of 
all such activities, as well as the net cost of each individual 
activity, is reasonable and allocable to the contract work. 
Additionally, advance understandings with respect to the costs mentioned 
in paragraph (a) of this section are to be reached prior to the 
incurrence of these costs as required in 970.3101-6.
    (c) Losses from the operation of food or dormitory services may be 
included as costs incurred under paragraph (b) of this section, only if 
the contractor's objective is to operate such services at least on a 
break-even basis. Losses sustained because food services or lodging 
accommodations are furnished without charge or at prices or rates which 
obviously would not be conducive to accomplishment of the above 
objective, are not allowable, except in those instances where the 
contractor can demonstrate that unusual circumstances exist, such that, 
even with efficient management, operation of the services on a break-
even basis would require charging inordinately high prices, or prices or 
rates higher than those charged by commercial establishments offering 
the same services in the same geographical areas. Typical examples of 
such unusual circumstances are: (1) Where the contractor must provide 
food or dormitory services at remote locations where adequate commercial 
facilities are not reasonably available, or (2) where it is necessary to 
operate a facility at a lower volume than the facility could 
economically support.

[[Page 449]]

Cost of food and dormitory services shall include an allocable share of 
indirect expenses pertaining to these activities.
    (d) In those situations where the contractor has an arrangement 
authorizing an employee association to provide or operate a service such 
as vending machines in the contractor's plant, and retain the profits 
derived therefrom, such profits shall be treated in the same manner as 
if the contractor were providing the service (but see paragraph (e) of 
this section).
    (e) Contributions by the contractor to an employee organization, 
including funds set over from vending machines receipts or similar 
sources, may be included as cost incurred under paragraph (b) of this 
section, only to the extent that the contractor demonstrates that an 
equivalent amount of the costs incurred by the employee organization 
would be allowable, if incurred by the contractor directly.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.3102-6  Facilities (plant and equipment).

    (a) Use of Government-owned facilities. If the Government furnishes 
to the contractor, or the contractor acquires at Government expense, 
Government-owned equipment with which to do all or a significant amount 
of the work under the DOE contract, on which equipment the Government is 
bearing the expenses of depreciation, maintenance, insurance, and taxes, 
appropriate procedures must be established to avoid apportioning to DOE 
work performed with DOE-owned equipment, a share of the expenses of 
depreciation, maintenance, insurance and taxes on the contractor's 
equipment not used to perform such work. If the Government-owned 
equipment is placed in a segregated area, that area should be accounted 
for as a separate department. If the Government-owned equipment is not 
placed at the separate area, other steps must be taken to avoid what 
would amount to a double equipment burden on work performed with the 
Government-owned facilities. Such work shall be so accounted for as to 
be relieved of charges for expenses related to contractor's equipment 
not used in its performance.
    (b) Contractor's costs covering plant and equipment. Charges 
relating to contractor-owned plant and equipment shall be restricted to 
the applicable costs, such as depreciation, maintenance, insurance, and 
taxes, and shall not be on a rental basis. (Compensation in excess of 
costs is covered by the fixed fee.) Rentals of plant or equipment owned 
by third parties are normally allowable, if the rates are reasonable in 
the light of the type, value, condition of the property involved, and 
option and other provisions of the lease agreement. However, where the 
plant and equipment used by the contractor is rented by the contractor 
under a sale and lease-back agreement, only the normal costs (such as 
depreciation, maintenance, insurance, and taxes) that would have been 
incurred if the contractor had retained title to the facilities, should 
be allowed. Allowances for plant and equipment rented under agreements 
that are not arms-length transactions should be similarly restrictive.



970.3102-7  Legislative lobbying costs.

    Contractor costs incurred to influence (directly or indirectly) 
legislative action on any matter pending before Congress or a State 
legislature are not allowable contract costs and shall not be reimbursed 
by DOE. This statutory based cost prohibition (See 42 U.S.C. 7256a, as 
amended) is specified in the applicable cost principles clauses at 
970.5204-13(e)(31) or 970.5204-14(e)(29). Definitive cost principle 
criteria for determining the types of legislative liaison activity costs 
which are not reimbursable under M&O contracts are set forth in the 
contract clause at 970.5204-17. The referenced clauses are effective, 
retroactively, as of January 14, 1987, and any change made to the cost 
principle criteria specified therein constitutes a deviation requiring 
Procurement Executive approval pursuant to 970.3100-3.
[53 FR 21648, June 9, 1988]

[[Page 450]]



970.3102-8  Membership in trade, business and professional organizations.

    (a) The costs of memberships in trade, business and technical 
organizations are unallowable, except as approved by the contracting 
officer.
    (b) In considering approval of membership dues, the contracting 
officer shall:
    (1) Ensure that dues payments to an organization are clearly 
justified and provide necessary and specific agency benefit;
    (2) Do not constitute payments for, or in support of partisan and 
political activity; and,
    (3) Are solely for purposes of enhancing trade, business, or 
technical knowledge necessary for, and related to, performance of DOE 
contracts.



970.3102-9  Outside technical and professional consultants.

    Technical and professional consultants, as used here, refer to 
private individuals acting in their own behalf, who make their services 
available on a fee or per diem basis. It does not refer to employees of 
firms acting in the firm's behalf whose services may be made available 
by the firm on, for example, a fixed rate basis. Consultant arrangements 
may permit bringing to contract work, the services of outstanding 
specialists who would not be available on a full-time basis, or whose 
employment on a full-time basis would not be economically feasible. 
Costs of such outside consultant services are normally allowable 
(however, see 970.5204-13 and 970.5204-14 regarding compensation of an 
individual who is employed by another contractor and concurrently 
performing work on a full-time annual basis under a DOE cost-type 
contract), provided that the services are essential to, and will make a 
material contribution to, the performance of contract work; the services 
may be performed more economically or more successfully by a consultant 
than by the contractor's regular personnel; the fee or per diem charged 
is reasonable; and, when approved by the contracting officer. If the 
cost of such services is charged directly to the DOE contract, the cost 
of like items properly chargeable only to other work of the contractor 
must be eliminated from indirect costs allocable to the DOE contract 
(see 970.3101-2).
[49 FR 12063, Mar. 28, 1984; 49 FR 38953, Oct. 2, 1984, as amended at 59 
FR 9110, Feb. 25, 1994]



970.3102-10  Overtime, shift, and holiday premiums.

    (a) Overtime, shift, and holiday premiums are allowable only to the 
extent provided in the contract or approved by the contracting officer. 
The amount of such premiums charged to a management and operating 
contract shall be equitable in relation to the amount of such costs 
charged to other work currently performed in the contractor's plant and 
the factors which necessitate incurrence of the costs. When the 
necessity for overtime, shift, and holiday work arises from inadequacy 
of the contractor's plant or department to perform its total workload on 
a purely straight-time basis, inclusions in overhead for apportionment 
to all work of the plant or department, as the case may be, appears 
appropriate. When particular work, DOE or other, is being specially 
expedited to a point that its fair share of the contractor's purely 
straight-time efforts on a single-shift basis will not get the 
particular job completed within the time desired, direct charging of the 
related premiums appears appropriate.
    (b) When premiums for overtime, shift, and holiday work are charged 
direct to the work concerned, if the operating overhead of the plant or 
related department is distributed on the basis of direct labor (cost or 
hours), the premiums should be excluded from the direct labor base for 
purposes of overhead distribution. That is, the direct labor base should 
be, as appropriate, direct labor straight-time cost or direct labor 
hours actually worked. While the premiums for authorized overtime, 
shift, and holiday work are acceptable as reimbursable costs, it is 
generally recognized that direct labor hours worked on an overtime, 
shift, or holiday basis should participate in indirect costs to the same 
extent as hours worked on a straight-time basis.

[[Page 451]]



970.3102-11  Page charges in scientific journals.

    It is a policy of the DOE to permit DOE contractors to budget for 
and pay page charges for scientific journal publication, as a necessary 
part of research costs, in all cases where:
    (a) The research papers report work supported by the Government.
    (b) The charges are levied impartially on all research papers 
published by the journal, whether by non-Government or by Government 
authors.
    (c) Payment of such charges is in no sense a condition for 
acceptance of manuscripts by the journal.
    (d) The journals involved are not operated for profit.
    (e) The author does not receive an emolument from the journal for 
the research paper.



970.3102-12  Plant reconversion costs.

    Plant reconversion costs are those incurred in the restoration of 
the contractor's facilities to approximately the same condition existing 
immediately prior to the commencement of the contract work, fair wear 
and tear excepted.



970.3102-13  Precontract costs.

    Precontract costs are those incurred prior to the effective date of 
the contract directly pursuant to the negotiation and in anticipation of 
the award of the contract, where such incurrence is necessary to comply 
with the proposed contract delivery schedule. Such costs are allowable 
to the extent that they would have been allowable if incurred after 
effective the date of the contract. They do not include costs of 
preparing bids or of participation in the negotiation. The allowability 
of precontract costs is dependent upon appropriate coverage in the 
contract.



970.3102-14  Preparatory and make-ready costs.

    Since indirect costs are usually apportioned to individual jobs 
wholly or substantially on the basis of the direct labor applied to the 
particular job, a contract will absorb no overhead by apportionment 
prior to the inception of the actual performance of direct work on the 
contract. The effort of the contractor's overhead organization in 
preparing for one job and in getting it underway, will thus be absorbed 
by jobs previously commenced and still being performed; later, the job, 
which in its initial stages of preparation and make-ready was relieved 
of expenses that were actually applicable to it, will partially absorb, 
through their apportionment as overhead, similar costs equally 
applicable in fact to other, subsequently undertaken jobs. This 
procedure is in accordance with generally accepted accounting practices 
and normally is reasonably equitable in its results. The initial 
advantages and subsequent disadvantages to the individual contract that 
result from consistent application of the procedure tend to offset each 
other and balance out. It is quite appropriate, however, to employ the 
direct charge method in connection with overhead costs in preparing for 
actual performance by segregating such preparatory and make-ready costs 
and identifying them specifically with the contract to which the effort 
actually pertains. However, if preparatory and make ready costs are 
charged direct to a DOE contract, care must be taken, as performance of 
the DOE contract work proceeds toward completion, to segregate 
subsequent indirect expenses similarly applicable to the preparation 
for, and commencement of, other jobs and to account for them as direct 
charges to those other jobs.



970.3102-15  Procurement: Subcontracts, contractor-affiliated sources, and leases.

    (a) Subcontracts. Award and management policies for subcontracts 
placed under operating contracts when necessary to the performance of 
the required services and work efforts of the management and operating 
contractor are set forth in 970.71. The cost of performing such 
subcontracts shall be allowable under the DOE contract when (1) the 
award/approval is otherwise in accord with the contract terms and 
conditions and the provisions of 970.71 and (2) the reimbursement of 
subcontractor costs of the management and operating contractor is in 
accordance with the provisions of the DOE cost principles set forth in 
FAR 31, as appropriate to the type of subcontractor being selected; 
i.e., commercial,

[[Page 452]]

educational, state/local government, or nonprofit organization.
    (b) Procurement or transfer from contractor-affiliated sources (See 
970.7105). Allowance for all equipment, materials, supplies, and 
services which are sold or transferred between any division, subsidiary, 
or affiliate of a management and operating contractor under a common 
control shall be on the basis of cost incurred in accordance with the 
terms of the contract; except, when it is the established practice of 
the transferring organization to price inter-organization transfers of 
equipment, materials, supplies, and services at other than cost for 
commercial work of the contractor or any division, subsidiary, or 
affiliate of the contractor under a common control, allowance may be at 
a price when:
    (1) It is based on an ``established catalog or market price of 
commercial items sold in substantial quantities to the general public'' 
in accordance with FAR 15.8 or
    (2) It is the result of ``adequate price competition'' in accordance 
with FAR 15.8 and is the price at which an award was made to the 
affiliated organization, after obtaining quotations of an equal basis 
from such organization and one or more outside sources which normally 
produce the item or its equivalent in significant quantity, provided 
that in either case:
    (i) The price is not in excess of the transferor's current sales 
price to its most favored customer (including any division, subsidiary, 
or affiliate of the contractor under a common control) for a like 
quantity under comparable conditions, and
    (ii) The price is not determined to be unreasonable by the 
contracting officer, provided, however, that if the price is determined 
unreasonable, such determination must be supported by an enumeration of 
facts on which it is based and approved at a level above the contracting 
officer. The price determined in accordance with paragraph (a) of this 
section should be adjusted, when appropriate, to reflect the quantities 
being procured and may be adjusted upward or downward to reflect the 
actual cost of any modifications necessary because of contract 
requirements.
    (c) Leases. Contractor lease payments will be considered an 
allowable cost when a leasing arrangement is not prohibited by the 
contract terms (e.g., see 970.5204-22). If a lease for property, plant 
or equipment (land and/or depreciable assets) is required to be 
classified as a capital lease under generally accepted accounting 
principles (GAAP), imputed interest costs determined in accordance with 
GAAP for any such contractor lease shall be an allowable contract charge 
if the following are met:
    (1) The specific decision to enter into a capital leasing 
arrangement is authorized by DOE in accordance with applicable DOE 
procedures, prior to execution of the lease,
    (2) The lease is accounted for in accordance with GAAP, and
    (3) The imputed interest costs are separately accounted for in 
special DOE accounts established for the recordation of such costs.
[49 FR 12063, Mar. 28, 1984, as amended at 53 FR 24231, June 27, 1988; 
55 FR 41540, Oct. 12, 1990]



970.3102-16  Relocation costs.

    (a) Relocation costs are costs incident to the permanent change of 
duty assignment (for an indefinite period or for a stated period of not 
less than 12 months) of an existing employee or upon recruitment of a 
new employee. The following types of costs are allowable as noted, 
subject to provisions of paragraphs (b), (c), and (d) of this section.
    (1) Costs of travel of the employee and members of his/her immediate 
family and transportation of household and personal effects to the new 
location.
    (2) Costs of finding a new home, such as advance trips by employees 
and spouses to locate living quarters, and temporary lodging during the 
transition periods, not exceeding separate cumulative totals of 60 days 
for employees and 45 days for spouses and dependents, including advance 
trip time.
    (3) Closing costs (i.e., brokerage fees, legal fees, appraisal fees, 
points, finance charges, etc.) incident to the disposition of actual 
residence owned by the employee when notified of transfer; Provided that 
closing costs when added

[[Page 453]]

to the continuing costs described in (a)(6) of this section shall not 
exceed 14% of the sales price of the property sold.
    (4) Other necessary and reasonable miscellaneous expenses incident 
to relocation, such as disconnection and connecting household 
appliances; automobile registration; drivers license and use taxes; 
cutting and fitting rugs, draperies, and curtains; forfeited utility 
fees and deposits; and purchase of insurance against damage to or loss 
of personal property while in transit.
    (5) Costs incident to the acquisition of a home in a new location, 
except that these costs will not be allowable for existing employees or 
newly recruited employees who prior to the relocation were not 
homeowners and the total costs shall not exceed 5% of the purchase price 
of the new home.
    (6) Continuing costs of ownership of the vacant former actual 
residence being sold, such as maintenance of building and grounds 
(exclusive of fixing up expenses), utilities, taxes, property insurance, 
mortgage interest, etc., after settlement date or lease date of new 
permanent residence; Provided that when added to the closing costs 
described in (a)(3) of this section, the costs shall not exceed 14% of 
the sales price of the property sold.
    (7) Mortgage interest differential payments, except that these costs 
are not allowable for existing or newly recruited employees who prior to 
the relocation were not homeowners, and the total payments are limited 
to an amount determined as follows:
    (i) Difference between the mortgage interest rates of the old and 
new residence times the current balance of the old mortgage times 3 
years; and
    (ii) When mortgage differential payments are made on a lump sum 
basis and the employee leaves or is transferred again in less than 3 
years, the amount initially recognized shall be proportionately adjusted 
to reflect payments only for the actual time of the relocation.
    (8) Rental differential payments covering situations where relocated 
employees retain ownership of a vacated home in the old location and 
rent at the new location. The rented quarters at the new location must 
be comparable to those vacated, and the allowable differential payment 
may not exceed the actual rental costs for the new home, less the fair 
market rent for the vacated home times 3 years.
    (9) Cost of canceling an unexpired lease.
    (b) The costs described in (a) of this section must also meet the 
following criteria to be considered allowable.
    (1) The move is for the benefit of the Government.
    (2) Reimbursement must be in accordance with an established policy 
or practice and program that is consistently followed and is designed to 
motivate employees to relocate promptly and economically.
    (3) Amounts to be reimbursed do not exceed the employee's actual 
expenses, except that for miscellaneous costs of the type discussed in 
(a)(4) of this section, a flat amount, not to exceed $1,000, may be paid 
in lieu of actual costs.
    (c) The following types of costs are not allowable:
    (1) Loss on sale of a home.
    (2) Continuing mortgage principle payments on residence being sold.
    (3) Cost incident to the acquisition of a home in a new location as 
follows:
    (i) Real estate brokers fees and commissions;
    (ii) Costs of litigation;
    (iii) Real and personal property insurance against damage or loss of 
property;
    (iv) Mortgage life insurance;
    (v) Owner's title policy insurance when such insurance was not 
previously carried by the employees on the old residence (however, costs 
of a mortgage title policy is allowable) and;
    (vi) Property taxes and operating or maintenance costs.
    (4) Payments for employee's income taxes or FICA (social security 
taxes) incident to reimbursed relocation costs.
    (5) Costs incident to furnishing equity or nonequity loans to 
employees or making arrangements with lenders for employees to obtain 
lower-than-market rate mortgage loans.
    (d) If relocation costs for an employee have been allowed and the 
employee resigns within 12 months for reasons within the employee's 
control,

[[Page 454]]

it is expected the contractor shall refund or credit the relocation 
costs to the Government.
    (e) Contractor payments to an independent relocation assistance firm 
handling acquisitions and sales of houses of transferred employees are 
allowable in amounts which otherwise represent payment for itemized cost 
which are allowable in accordance with the provisions of this section.
[49 FR 12063, Mar. 28, 1984, as amended at 54 FR 27649, June 30, 1989]



970.3102-17  Travel costs.

    (a)(1) Commercial air travel. It is the policy of the DOE to require 
management and operating contractors to use the lowest commercial 
airfare accommodations for all necessary travel under the contract, 
except when such accommodations are not reasonably available. Airfare 
costs in excess of the lesser of the lowest available commercial 
discount airfare, Government contract airfare, or customary standard 
(coach or equivalent) airfare, shall be disallowed except where the use 
of such accommodations would: Require circuitous routing; require travel 
during unreasonable hours; excessively prolong travel; result in 
increased cost that would offset transportation savings; would offer 
accommodations not reasonably adequate for the physical or medical needs 
of the traveler; or are not reasonably available to meet necessary 
mission requirements. The contractor shall be required to establish 
appropriate airfare travel policies and procedures requiring the use of 
the lowest available commercial airfare consistent with the foregoing 
and prudent travel management. Where a contractor can reasonably 
demonstrate to the contracting officer, or designee, the nonavailability 
of discount airfare or Government contract airfare for a particular trip 
or, on an overall basis, that it is the contractor's practice to make 
routine use of such airfare, specific contractor determinations of 
nonavailability should generally not be questioned, unless a pattern of 
avoidance is detected. However, in order for airfare costs in excess of 
the customary standard commercial airfare to be allowable; e.g., use of 
first-class airfare, the contractor must be able to justify and document 
on a case-by-case basis the applicable condition(s) set forth above.
    (2) Air travel by other than commercial carrier. Cost of travel by 
contractor-owned, -leased, or -chartered aircraft, as used in this 
paragraph, includes the cost of lease, charter, operation (including 
personnel costs), maintenance, depreciation, insurance and other related 
costs. Costs of travel via contractor-owned, -leased, and -chartered 
aircraft shall not exceed the cost of commercial air travel 
accommodations, unless the management and operating contractor can 
demonstrate that costs in excess of such amounts are necessary for 
contract performance and that the increase in cost, if any, in 
comparison with alternative means of transportation is commensurate with 
the advantage gained.
    (b) Government-owned or commercial rental vehicles. Commercial 
rental automobile costs in excess of the cost of a Government-furnished 
automobile or, when a Government-furnished automobile is not available, 
the cost of a Government-contract rental automobile available under a 
GSA Federal Supply Schedule contract, is unallowable unless:
    (1) A Government-furnished or a Government contract rental 
automobile is not reasonably available to the traveler, or
    (2) The traveler's use and the cost of a commercial rental 
automobile are justified and authorized as more advantageous to the 
Government.
    (c) Lodging, meals and incidental expenses. (1) Costs for lodging, 
meals, and incidental expenses incurred by management and operating 
contractor personnel traveling on official business in the performance 
of contract work are allowable costs but subject to the limitations set 
forth in this subsection. Payments for lodging, meals, and incidental 
expenses may be based on per diem, actual expenses, or a combination 
thereof, provided the method used results in a reasonable cost to DOE.
    (2) Except as provided in paragraph (c)(3) of this section, 
management and operating contractor payments for lodging, meals, and 
incidental expenses (as defined in the regulations cited in paragraphs 
(c)(2) (i) through (iii) of this

[[Page 455]]

section) shall be considered to be reasonable and allowable cost only to 
the extent that they do not exceed, on a daily basis, the maximum per 
diem rates in effect at the time of travel as set forth in the:
    (i) Federal Travel Regulation prescribed by the General Services 
Administration, for travel in the conterminous 48 United States.
    (ii) Joint Travel Regulations, Volume 2, DOD Civilian Personnel, 
Appendix A. prescribed by the Department of Defense, for travel in 
Alaska, Hawaii, the Commonwealth of Puerto Rico, and territories and 
possessions of the United States; or
    (iii) Standardized Regulations (Government Civilians, Foreign 
Areas), section 925, ``Maximum Travel Per Diem Allowances for Foreign 
Areas,'' prescribed by the Department of State, for travel in areas not 
covered in paragraphs (c)(2) (i) and (ii) of this section.
    (3) In special or unusual situations, management and operating 
contractor personnel may be paid for actual expenses in excess of the 
above-referenced maximum per diem rates provided such payments do not 
exceed the higher amounts authorized for Federal civilians employees as 
permitted in the regulations referenced in paragraph (c)(2) (i), (ii) or 
(iii) of this section and all of the following conditions are met:
    (i) One of the conditions warranting approval of the actual expense 
method, as set forth in the regulations referenced in paragraph 
(c)(2)(i), (ii) or (iii) of this section exist.
    (ii) A written justification for payment of the higher amounts is 
approved by an officer or appropriate official of the management and 
operating contractor's organization.
    (iii) Documentation exists to support the payment of actual expenses 
incurred and each employee expenditure in excess of $25.00 is supported 
by a receipt. The approved justification required by paragraph 
(c)(3)(ii) and, if applicable, DOE advance approvals required under 
paragraph (c)(5) of this section must also be retained.
    (4) Paragraphs (c)(2) and (c)(3) of this section do not incorporate 
the regulations cited in paragraphs (c)(2) (i), (ii) and (iii) of this 
section in their entirety. Only the coverage in the referenced 
regulations dealing with special or unusual situations, the maximum per 
diem rates and the definitions of lodging, meals and incidental expenses 
are to be applied to management and operating contractors.
    (5) An advance agreement with respect to compliance with paragraphs 
(c)(2) and (c)(3) of this section will be established in the personnel 
appendix of the contract. The management and operating contractor shall 
also be required to obtain advance approval from DOE, if it becomes 
necessary for the contractor to exercise the authority to make payments 
based in the higher actual expense method repetitively or on a 
continuing basis in a particular area. It is not intended that 
individual contractor authorizations to pay actual expenses in excess of 
applicable maximum per diem rates be approved in advance by DOE. Such 
before the fact, case-by-case approvals should only be invoked when the 
management and operating contractor does not have acceptable travel cost 
policies, procedures or practices in effect.
    (6)(i) The maximum per diem rates referenced in paragraph (c)(2) of 
this section generally would not constitute a reasonable daily charge:
    (A) When no lodging costs are incurred; and/or
    (B) On partial travel days (e.g., same day of departure and return).
    (ii) Appropriate downward adjustments from the maximum per diem 
rates would normally be required under these circumstances. While these 
adjustments need not be calculated pursuant to the Federal Travel 
Regulation, Joint Travel Regulations, or Standardized Regulations, they 
must result in a reasonable charge.
[49 FR 12063, Mar. 28, 1984 and 51 FR 43926, Dec. 5, 1986, as amended at 
52 FR 1608, Jan. 14, 1987; 59 FR 9110, Feb. 25, 1994; 60 FR 30006, June 
7, 1995]



970.3102-18  Special funds in the construction industry.

    Costs of special ``funds,'' financed by employer contributions, in 
the construction industry for such purposes as methods and materials 
research, public

[[Page 456]]

and industry relations, market development, disaster relief, etc., are 
unallowable, except as specifically authorized by the contracting 
officer and provided for in the contract.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.3102-19  Public relations and advertising.

    (a) Public relations means all functions and activities dedicated 
to:
    (1) Maintaining, protection, and enhancing the image of a concern or 
its products; or
    (2) Maintaining or promoting reciprocal understanding and favorable 
relations with the public at large, or any segment of the public. The 
term ``public relations'' includes activities associated with areas such 
as advertising, customer relations, community service, etc.
    (b) Advertising means the use of media to promote the sale of 
products or services and to accomplish the activities referred to in 
paragraph (d) of this section regardless of the medium employed, when 
the advertiser has control over the form and content of what will 
appear, the media in which it will appear, and when it will appear. 
Advertising media include but are not limited to conventions, exhibits, 
free goods, samples, magazines, trade papers, direct mail, dealer cards, 
window displays, outdoor advertising, radio, and television.
    (c) Public relations and advertising costs include the costs of 
media time and space, purchased services performed by outside 
organizations, as well as the applicable portion of salaries, travel, 
and fringe benefits of employees engaged in the functions and activities 
identified in paragraphs (a) and (b) of this section.
    (d) The only advertising costs that are allowable are those 
specifically required by contract, approved in advance by the 
contracting officer, or that arise from requirements of the contract and 
that are exclusively for:
    (1) Recruiting personnel required for contract performance;
    (2) Acquiring scarce items for contract performance;
    (3) Disposing of scrap or surplus materials acquired for contract 
performance;
    (4) The transfer of federally owned or originated technology to 
State and local governments and to the private sector; or
    (5) Obtaining supplies and services including contract-required 
equipment, leases, banking services, etc.

Costs of this nature are allowable to the extent that they are 
determined by the contracting officer to be reasonable, necessary, and 
incident to contract performance.
    (e) Allowable public relations costs include the following:
    (1) Costs specifically required by contract, or approved in advance 
by the contracting officer.
    (2) Costs of--
    (i) Responding to inquiries on company policies and activities.
    (ii) Communicating with the public, press, stockholders creditors, 
local communities, and customers, including responses to inquiries from 
and initiation of press releases and other communications with the news 
media.
    (iii) Conducting general liaison with news media and government 
public relations officers, to the extent that such activities are 
limited to communication and liaison necessary to keep the public 
informed on matters of public concern such as notice of contract awards, 
plant closures or openings, employee layoffs or rehires, financial 
information environmental impact of plant operations, etc.
    (3) Costs of participation in community service activities (e.g., 
blood bank drives, charity drives, savings bond drives, disaster 
assistance, outreach programs, etc.), exclusive of contractor cash 
contributions and donations which are unallowable. The contractor's cost 
of services or contractor-owned property provided to support community 
service activities (e.g., the contractor's cost of making payroll 
deductions for employee contributions to a charity, cost of employee 
services provided to community organizations, or other similar, nominal 
in-kind participation) is allowable.
    (4) Costs of plant tours, visitors centers, and open houses (but see 
paragraph (f)(5) of this section).

[[Page 457]]

    (f) Unallowable public relations and advertising costs include the 
following activities except when the principal purpose of the activity 
or event is to disseminate technical information or stimulate production 
in accordance with contract requirements:
    (1) All advertising costs other than those specified in paragraph 
(d) of this section.
    (2) Costs of air shows and other special events, such as conventions 
and trade shows including:
    (i) Costs of displays, demonstrations and exhibits;
    (ii) Costs of meeting rooms, hospitality suites, and other special 
facilities used in conjunction with shows and other special events; and
    (iii) Salaries and wages of employees engaged in setting up and 
displaying exhibits, making demonstrations, and providing briefings.
    (3) Costs of sponsoring meetings, symposia, seminars, and other 
special events.
    (4) Costs of ceremonies such as corporate celebrations and new 
product announcements.
    (5) Costs of promotional material, motion pictures, videotapes, 
brochures, handouts, magazines, and other media that are designed to 
benefit the contractor's organization by calling favorable public 
attention to contractor activities.
    (g) Unallowable public relations and advertising costs include the 
following:
    (1) Costs of souvenirs, models, imprinted clothing, buttons, and 
other mementos provided to customers or the public.
    (2) Cost of memberships in civic and community organizations.
    (3) All advertising and public relations costs, other than as 
specified in paragraphs (d), (e) and (f) of this section, whose primary 
purpose is to benefit the contractor's organization by promoting the 
sale of products or services by stimulating interest in a product or 
product line or by disseminating messages calling favorable attention to 
the contractor for purposes of enhancing the company image to sell the 
company's products or services unless such sales activities are required 
under the management and operating contract to support the DOE mission. 
Nothing in this paragraph (g)(3) modifies the express unallowability of 
costs listed in paragraphs (f), (g)(1) and (g)(2) of this section. The 
purpose of this paragraph is to provide criteria for determining whether 
advertising and public relations costs not specifically identified 
should be unallowable.
[52 FR 1608, Jan. 14, 1987, as amended at 59 FR 9110, Feb. 25, 1994]



970.3102-20  Cost prohibitions related to legal and other proceedings.

    (a) Contractor costs incurred in connection with a criminal, civil 
or administrative proceeding involving contractor violation of, or 
failure to comply with, a Federal, State, local or foreign statute or 
regulation are subject to the allowable costs limitations established in 
section 8 of the Major Fraud Act of 1988, Public Law 100-700 (see 41 
U.S.C. 256).
    (b) Implementation of the Major Fraud Act's contract cost 
limitations is specified in the applicable cost principles clauses at 
970.5204-13(e)(33) or 970.5204-14(e)(31). Definitive cost principle 
criteria for determining the allowability of an M&O contractor's costs 
incurred in connection with a criminal, civil or administrative 
proceeding are set forth in the contract clause at 970.5204-61. Any 
change made to the cost principle criteria specified therein constitutes 
a deviation requiring Procurement Executive approval pursuant to 
970.3100-3.
[58 FR 61628, Nov. 22, 1993]



970.3102-21  Fines and penalties.

    It is Department of Energy policy not to reimburse management and 
operating contractors for fines and penalties except as provided in 48 
CFR (DEAR) 970.5204-13(e)(12), Allowable Costs and Fixed Fee (Management 
and Operating Contracts), 48 CFR (DEAR) 970.5204-14(e)(10), Allowable 
Costs and Fixed Fee (Support Contracts), and 48 CFR (DEAR) 970.5204-75, 
Preexisting Conditions.
[62 FR 34865, June 27, 1997]



970.3103  Contract clauses.

    (a) The appropriate cost principles clause at 970.5204-13 or 
970.5204-14 shall

[[Page 458]]

be included in a management and operating contract.
    (b) The legislative lobbying cost prohibition clause at 970.5204-17 
shall be included in all M&O contracts.
    (c) The clause setting forth cost prohibitions related to legal and 
other proceedings at 970.5204-61 shall be included in all M&O contracts.
    (d) The clause at 970.5204-75, Preexisting Conditions, shall be 
included in management and operating contracts. Alternate I of the 
clause shall be inserted in management and operating contracts with 
incumbent contractors. Alternate II shall be inserted in contracts with 
contractors not previously working at that particular site or facility.
[49 FR 12090, Mar. 28, 1984. Correctly designated at 52 FR 1610, Jan. 
14, 1987, and amended at 53 FR 21648, June 9, 1988; 58 FR 61628, Nov. 
22, 1993; 62 FR 34865, June 27, 1997]



                   Subpart 970.32--Contract Financing



970.3201  General.

    It is the policy of the DOE to finance management and operating 
contracts through advance payments and use of Special Bank Accounts. 
Appropriate procedures for properly managing and controlling funds for 
obligation and expenditure under a management and operating contract are 
maintained by the Chief Financial Officer, Headquarters.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.3202  Advance payments.

    (a) The Head of the Contracting Activity, shall authorize advance 
payments without interest; and approve the findings, determinations and 
the contract terms and conditions concerning advance payments in 
accordance with the procedures set forth in FAR Subpart 32.4, Advance 
Payments, as amended by subpart 932.4.
    (b) Advance payments shall be made under a letter-of-credit 
arrangement for deposit in a special bank account.
    (c) Prior to providing any advance payments, the contracting officer 
shall enter into an agreement with the contractor and a financial 
institution, regarding a special bank account where the advanced funds 
are to be deposited by the Government. Such agreement shall (1) provide 
that DOE shall retain title to the unexpended balance of funds in the 
special bank account including revenues if any, deposited by the 
contractor; and that such title shall be superior to any claim or lien 
of the bank of deposit and (2) incorporate as necessary or appropriate, 
additional financial provisions required by Treasury or Departmental 
financial regulations.
    (d) Deviations from these specified requirements cited in paragraph 
(c) above shall be considered a deviation requiring approval of the Head 
of the Contracting Activity.
    (e) Letter-of-Credit arrangements shall be prepared in accordance 
with FAR 32.406, Letters of Credit, and shall be coordinated between the 
procurement and finance organizations.



970.3270  Clauses.

    The clauses at 970.5204-16 shall be included in management and 
operating contracts when advances of funds are to be placed in a special 
bank account. They may be appropriately modified to incorporate any 
additional provisions that may be required by governing financial 
regulations of the Treasury Department or the Department.



970.3271  Special bank account agreement.

    Note: The following agreement shall be used with special bank 
accounts in accordance with 970.3202(c).
    Agreement entered into this ____ day of ______, 19____, between the 
United States of America (hereinafter called the Government) represented 
herein by the Department of Energy (hereinafter called the ``DOE''), and 
________ (hereinafter called the ``Contractor,'' a corporation under the 
laws of the State of ________, and ________, (hereinafter called the 
``Bank,'') a banking corporation under the laws of ________, located at 
________.

                                Recitals

    (a) On the date of ______, 19____, DOE and the Contractor entered 
into Contract(s) No. ________, or a supplemental agreement thereto, 
providing for the making of advances of Government funds to the 
contractor a copy of such advance provisions has been furnished to the 
Bank.

[[Page 459]]

    (b) DOE requires that amounts advanced to the Contractor under said 
contract or supplemental agreement be deposited in a Special Bank 
Account or accounts with a bank designated by the Treasury Department as 
depositary and financial agent of the Government (Section 10 of the Act 
of June 11, 1942, 56 Stat. 356; 12 U.S.C. 265), separate from any of the 
Contractor's general or other funds; and, the Bank being such a bank, 
the parties are agreeable to so depositing said amounts with the Bank.
    (c) This Special Bank Account shall be designated ``________ (Name 
of Contractor), ______ (Contract Number), Department of Energy Special 
Bank Account.''

                                Covenants

    In consideration of the foregoing, and for other good and valuable 
considerations, it is agreed that,
    (1) The Government shall have title to the credit balance in said 
account to secure the return of all advances made to the contractor, 
which title shall be superior to any lien or claim of the Bank or others 
with respect to such account.
    (2) The Bank will be bound by the provisions of said contract or 
contracts relating to the deposit and withdrawal of funds in the above 
Special Bank Account, but shall not be responsible for the application 
of funds properly withdrawn from said account. After receipt by the Bank 
of written directions from the contracting officer, or from the duly 
authorized representative of the contracting officer, the Bank shall act 
thereon and shall be under no liability to any party hereto for any 
action taken in accordance with the said written directions.
    (3) The Government, or its authorized representatives, shall have 
access to the books and records maintained by the Bank with respect to 
such Special Bank Account at all reasonable times and for all reasonable 
purposes, including, without limitation, the inspection or copying of 
such books and records and any and all memoranda, checks, 
correspondence, or documents pertaining thereto. Except as agreed upon 
by the Government and the Bank, all books and records pertaining to the 
Special Bank Account in the possession of the Bank relating to the 
Special Bank Account agreement shall be preserved by the Bank for a 
period of three (3) years after final payment under the contract to 
which the Special Bank Account agreement pertains or otherwise disposed 
of in such manners as may be agreed upon by the Government and the Bank.
    (4) In the event of the services of any writ of attachment, levy of 
execution, or commencement of garnishment proceedings with respect to 
the Special Bank Account, the Bank will promptly notify the Head of the 
Contracting Activity, DOE.
    In witness whereof the parties hereto have caused this Agreement to 
be executed, as of the day and year first above written.

 (Signatures and Official Titles)_______________________________________
 _______________________________________________________________________
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



             Subpart 970.36--Construction and A-E Contracts



970.3601  Special construction clause for operating contracts.

    The clause in 970.5204-38 shall be used in management and operating 
contracts when the contractor will not perform covered work with its own 
forces but may procure construction by subcontract.
[49 FR 12063, Mar. 28, 1984. Redesignated at 53 FR 24231, June 27, 1988]



             Subpart 970.41--Acquisition of Utility Services



970.4100  General.

    (a) Utility services defined at FAR 41.101 for the furnishing of 
electricity, gas (natural or manufactured), steam, water, and/or 
sewerage to facilities owned or leased by DOE shall be acquired directly 
by DOE and not by a contractor using a subcontractor arrangement, except 
as provided in (b) below.
    (b) Where it is determined to be in the best interest of the 
Government, a Contracting Activity may authorize a management and 
operating contractor for a facility to acquire such utility service for 
the facility, after requesting and receiving concurrence to make such an 
authorization from the Director, Public Utilities Branch, Headquarters. 
Any request for such concurrence should be included in the Utility 
Service Requirements and Options Studies required by DOE directives in 
subseries 4540 (Public Services). Alternatively, it may be made in a 
separate document submitted to the Director of that office early in the 
acquisition cycle. Any request shall set forth why it is in the best 
interst of the DOE to acquire utilitiy service(s) by subcontract, i.e., 
what the benefits are, such as economic advantage.

[[Page 460]]

    (c) The requirements of FAR part 41, this section, and DOE 
directives in subseries 4540 shall be applied to a subcontract level 
acquisition for furnishing utility services to a facility owned or 
leased by DOE.
[56 FR 41965, Aug. 26, 1991, as amended at 59 FR 9109, Feb. 25, 1994. 
Redesignated and amended at 62 FR 2312, Jan. 16, 1997.]



                   Subpart 970.45--Government Property



970.4501  Contract clause.

    The contracting officer shall insert the clause at 970.5204-21, 
Property, in management and operating contracts. Paragraph (f)(1)(iii) 
applies to a nonprofit contractor only to the extent specifically 
provided in the individual contract.
[62 FR 34865, June 27, 1997]



                Subpart 970.49--Termination of Contracts



970.4901  General.

    All management and operating contracts, regardless of whether they 
are for production, research and development, or services, shall contain 
appropriate termination provisions.
[49 FR 12063, Mar. 28, 1984, as amended at 53 FR 24231, June 27, 1988]



970.4902  Termination clause.

    The clause at 970.5204-45 shall be inserted into management and 
operating contracts.



        Subpart 970.51--Use of Government Sources by Contractors



970.5101  Use of Government supply sources.

    (a) Management and operating contractors should meet their 
acquisition requirements from Government sources of supply, when these 
sources are made available to them and if it is economically 
advantageous or otherwise in the best interest of the Government.
    (b) Contracting officers may authorize management and operating 
contractors and their subcontractors with cost-reimbursement type 
subcontracts, where all higher-tier subcontracts are cost-reimbursement 
types, to acquire materials and services directly from such Government 
sources of supply in accordance with the requirements of this subpart or 
the consent of agencies involved.
    (c) Materials, supplies, and equipment procured from Government 
sources of supply under the procedures described herein must be used 
exclusively in connection with management and operating contract work, 
except as otherwise authorized by the Heads of Contracting Activities.
    (d) Many supply facilities and contracts of the Department of 
Defense are made available to DOE and its management and operating 
contractors. Accordingly:
    (1) Requisitions or purchase orders shall be submitted directly to 
these sources, unless otherwise specified. Field offices will be 
notified by the Procurement Executive, or designee, when such contracts 
and facilities are made available. Inquiries in connection with these 
sources may be directed to the Procurement Executive.
    (2) Contractor requisitions submitted to Defense Logistics Centers 
should include the following statement. ``The consignee of the supplies 
and materials requisitioned herein is acting in behalf of and as agent 
for the Department of Energy with respect to the expenditure of 
Government funds.'' Orders submitted directly to DOD contractors shall 
be accompanied by an authorization substantially similar to that in FAR 
51.103.
    (e) Contracting officers, when reviewing the procurement systems and 
methods of contractors that have been authorized to use Government 
sources of supply, shall assure that provision is made for documenting 
the justification of procurements from commercial sources of items 
available from Government sources of supply.
    (f) Direct procurement by DOE, rather than by a management and 
operating contractor, shall be required where deemed necessary by the 
Head of the Contracting Activity in order to carry out special 
requirements of appropriation acts or other applicable laws relating to 
particular items.

[[Page 461]]

    (g) The Procurement Executive shall be informed of instances in 
which Government sources of supply are not used because of the quality 
of the items available or when a Federal Supply Schedule contractor 
refuses to honor an order.
[49 FR 12063, Mar. 28, 1984; 49 FR 38953, Oct. 2, 1984, as amended at 59 
FR 9110, Feb. 25, 1994]



970.5102  Use of interagency motor pool vehicles and related services.

    The provisions of FAR subpart 51.2, FPMR 41 CFR 101-39, and DOE-PMR 
41 CFR 109-39 apply.



 Subpart 970.52--Contract Clauses for Management and Operating Contracts



970.5201  General policy.

    Many of the clauses set forth in subparts of FAR Part 52 and part 
952 of this chapter apply to management and operating contracts. The 
clauses in this subpart are to be used in addition to or in place of the 
FAR or the DEAR counterpart contract clauses where appropriate. Further 
modifications and notes to certain FAR clauses are also prescribed, in 
addition to those set forth in part 952.



970.5202  Deviations.

    Deviations from the standard contract clauses and modifications to 
FAR clauses set forth herein, as well as from the standard contract 
clauses prescribed in FAR Part 52 and part 952 of this chapter, shall be 
made only in accordance with the deviation procedures of subpart 901.4. 
Minor changes in wording which may become necessary in the course of 
negotiations are not considered deviations, provided Counsel determines 
that the change is not prohibited by statue, executive order, or 
administrative regulation and does not alter the meaning, intent, or 
basic principles expressed in these clauses.



970.5203  Modifications and notes to FAR clauses.



970.5203-1  Covenant against contingent fees.

    Insert the clause at (FAR) 48 CFR 52.203-5 with the addition of the 
following paragraph.
    (c) Subcontracts and purchase orders. Unless otherwise authorized by 
the contracting officer in writing, the contractor shall cause 
provisions similar to the foregoing to be inserted in all subcontracts 
and purchase orders entered into under this contract.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994; 60 
FR 49516, Sept. 26, 1995]



970.5203-2  [Reserved]



970.5203-3  Buy American Act.

    Insert the clause at (FAR) 48 CFR 52.225-3 but:

    Substitute ``use'' for ``deliver'' in paragraph (b).
[49 FR 12063, Mar. 28, 1984, as amended at 56 FR 41965, Aug. 26, 1991; 
59 FR 9110, Feb. 25, 1994]



970.5204  Clauses to be used in addition to or in place of the contract clauses set forth in FAR Part 52 and DEAR Part 952.



970.5204-1  Security.

    As prescribed in 970.0404-4 use the clauses at 952.204-2, Security 
and 952.204-70, Classification.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.5204-2  Integration of environment, safety, and health into work planning and execution.

    As prescribed in 48 CFR (DEAR) 970.2303-2(a), insert the following 
clause.

 Integration of Environment, Safety, and Health Into Work Planning and 
                          Execution (June 1997)

    (a) For the purposes of this clause,

[[Page 462]]

    (1) Safety encompasses environment, safety and health, including 
pollution prevention and waste minimization; and
    (2) Employees include subcontractor employees.
    (b) In performing work under this contract, the contractor shall 
perform work safely, in a manner that ensures adequate protection for 
employees, the public, and the environment, and shall be accountable for 
the safe performance of work. The contractor shall exercise a degree of 
care commensurate with the work and the associated hazards. The 
contractor shall ensure that management of environment, safety and 
health (ES&H) functions and activities becomes an integral but visible 
part of the contractor's work planning and execution processes. The 
contractor shall, in the performance of work, ensure that:
    (1) Line management is responsible for the protection of employees, 
the public, and the environment. Line management includes those 
contractor and subcontractor employees managing or supervising employees 
performing work.
    (2) Clear and unambiguous lines of authority and responsibility for 
ensuring ES&H are established and maintained at all organizational 
levels.
    (3) Personnel possess the experience, knowledge, skills, and 
abilities that are necessary to discharge their responsibilities.
    (4) Resources are effectively allocated to address ES&H, 
programmatic, and operational considerations. Protecting employees, the 
public, and the environment is a priority whenever activities are 
planned and performed.
    (5) Before work is performed, the associated hazards are evaluated 
and an agreed-upon set of ES&H standards and requirements are 
established which, if properly implemented, provide adequate assurance 
that employees, the public, and the environment are protected from 
adverse consequences.
    (6) Administrative and engineering controls to prevent and mitigate 
hazards are tailored to the work being performed and associated hazards. 
Emphasis should be on designing the work and/or controls to reduce or 
eliminate the hazards and to prevent accidents and unplanned releases 
and exposures.
    (7) The conditions and requirements to be satisfied for operations 
to be initiated and conducted are established and agreed-upon by DOE and 
the contractor. These agreed-upon conditions and requirements are 
requirements of the contract and binding upon the contractor. The extent 
of documentation and level of authority for agreement shall be tailored 
to the complexity and hazards associated with the work and shall be 
established in a Safety Management System.
    (c) The contractor shall manage and perform work in accordance with 
a documented Safety Management System (System) that fulfills all 
conditions in paragraph (b) of this clause at a minimum. Documentation 
of the System shall describe how the contractor will:
    (1) Define the scope of work;
    (2) Identify and analyze hazards associated with the work;
    (3) Develop and implement hazard controls;
    (4) Perform work within controls; and
    (5) Provide feedback on adequacy of controls and continue to improve 
safety management.
    (d) The System shall describe how the contractor will establish, 
document, and implement safety performance objectives, performance 
measures, and commitments in response to DOE program and budget 
execution guidance while maintaining the integrity of the System. The 
System shall also describe how the contractor will measure system 
effectiveness.
    (e) The contractor shall submit to the contracting officer 
documentation of its System for review and approval. Dates for 
submittal, discussions, and revisions to the System will be established 
by the contracting officer. Guidance on the preparation, content, 
review, and approval of the System will be provided by the contracting 
officer. On an annual basis, the contractor shall review and update, for 
DOE approval, its safety performance objectives, performance measures, 
and commitments consistent with and in response to DOE's program and 
budget execution guidance and direction. Resources shall be identified 
and allocated to meet the safety objectives and performance commitments 
as well as maintain the integrity of the entire System. Accordingly, the 
System shall be integrated with the contractor's business processes for 
work planning, budgeting, authorization, execution, and change control.
    (f) The contractor shall comply with, and assist the Department of 
Energy in complying with, ES&H requirements of all applicable laws and 
regulations, and applicable directives identified in the clause of this 
contract on Laws, Regulations, and DOE Directives. The contractor shall 
cooperate with Federal and non-Federal agencies having jurisdiction over 
ES&H matters under this contract.
    (g) The contractor shall promptly evaluate and resolve any 
noncompliance with applicable ES&H requirements and the System. If the 
contractor fails to provide resolution or if, at any time, the 
contractor's acts or failure to act causes substantial harm or an 
imminent danger to the environment or health and safety of employees or 
the public, the contracting officer may issue an order stopping work in 
whole or in part. Any stop work order issued by a contracting officer 
under this clause (or issued by the contractor to a subcontractor in 
accordance with paragraph
    (i) of this clause) shall be without prejudice to any other legal or 
contractual rights

[[Page 463]]

of the Government. In the event that the contracting officer issues a 
stop work order, an order authorizing the resumption of the work may be 
issued at the discretion of the contracting officer. The contractor 
shall not be entitled to an extension of time or additional fee or 
damages by reason of, or in connection with, any work stoppage ordered 
in accordance with this clause.
    (h) The contractor is responsible for compliance with the ES&H 
requirements applicable to this contract regardless of the performer of 
the work.
    (i) The contractor shall include a clause substantially the same as 
this clause in subcontracts involving complex or hazardous work on site 
at a DOE-owned or -leased facility. Such subcontracts shall provide for 
the right to stop work under the conditions described in paragraph (g) 
of this clause. Depending on the complexity and hazards associated with 
the work, the contractor may require that the subcontractor submit a 
Safety Management System for the contractor's review and approval.
[62 FR 34865, June 27, 1997]



970.5204-3  Buy American Act--construction materials.

    Include the clause at FAR 52.225-5 when the contract contains 
construction.



970.5204-4  New Mexico Gross Receipts and Compensating Tax.

    As prescribed in (FAR) 48 CFR 29.401-6(b), insert the clause at 
(FAR) 48 CFR 52.229-10, as modified by the following.

    In small paragraph (b) of this clause, replace the phrase 
``Allowable Cost and Payment clause'' with ``Allowable Costs and Fixed 
Fee Clause'' or, if it is different, the title of the clause addressing 
allowable costs.
[55 FR 5462, Feb. 15, 1990, as amended at 59 FR 9110, Feb. 25, 1994]



970.5204-5  Disclosure of information.

    As prescribed in 970.0404-4(b), insert the clause at 952.204-72.
[59 FR 9110, Feb. 25, 1994]



970.5204-6  Nuclear hazards indemnity.

    As prescribed in 950.7006(a), insert the clause at 952.250-70, when 
appropriate.
[59 FR 9110, Feb. 25, 1994]



970.5204-7  Protecting the Government's interest when subcontracting with contractors debarred, suspended, or proposed for debarment.

    Include the clause at FAR 52.209-6 as prescribed in FAR 9.409(b).
[60 FR 49516, Sept. 26, 1995]



970.5204-8  Indemnity assurance to architect-engineer or supplier prior to operation of a nuclear facility.

    As prescribed in 950.7006(a), insert the clause at 952.250-70, when 
appropriate.
[49 FR 12063, Mar. 28, 1984, as amended at 56 FR 57830, Nov. 14, 1991; 
59 FR 9110, Feb. 25, 1994]



970.5204-9  Accounts, records, and inspection.

    As prescribed in 970.0407, insert the following clause.

              Accounts, Records, and Inspection (JUN 1996)

    (a) Accounts. The contractor shall maintain a separate and distinct 
set of accounts, records, documents, and other evidence showing and 
supporting all allowable costs incurred, revenues or other applicable 
credits, fixed-fee accruals, and the receipt, use, and disposition of 
all Government property coming into the possession of the contractor 
under this contract. The system of accounts employed by the contractor 
shall be satisfactory to DOE and in accordance with generally accepted 
accounting principles consistently applied.

    Note: If the contract includes the clause for ``Price Reduction for 
Defective Cost or Pricing Data'' set forth at FAR 52.215-22, paragraph 
(a) above should be modified by adding the words ``or anticipated to be 
incurred'' after the words ``allowable costs incurred.''

    (b) Inspection and audit of accounts and records. All books of 
account and records relating to this contract shall be subject to 
inspection and audit by DOE at all reasonable times, before and during 
the period of retention provided for in (d) below, and the contractor 
shall afford DOE proper facilities for such inspection and audit.
    (c) Audit of subcontractors' records. The contractor also agrees, 
with respect to any subcontracts (including fixed-price or unit price 
subcontracts or purchase orders) where, under the terms of the 
subcontract, costs incurred are a factor in determining the amount 
payable to the subcontractor of any tier, to either conduct an audit of 
the subcontractor's costs or arrange for such an

[[Page 464]]

audit to be performed by the cognizant government audit agency through 
the contracting officer.
    (d) Disposition of records. Except as agreed upon by the Government 
and the contractor, all financial and cost reports, books of account and 
supporting documents, and other data evidencing costs allowable, 
revenues, and other applicable credits under this contract, shall be the 
property of the Government, and shall be delivered to the Government or 
otherwise disposed of by the contractor either as the contracting 
officer may from time to time direct during the progress of the work or, 
in any event, as the contracting officer shall direct upon completion or 
termination of this contract and final audit of accounts hereunder. 
Except as provided in this contract, all other records in the possession 
of the contractor relating to this contract shall be preserved by the 
contractor for a period of three years after final payment under this 
contract or otherwise disposed of in such manner as may be agreed upon 
by the Government and the contractor.
    (e) Reports. The contractor shall furnish such progress reports and 
schedules, financial and cost reports, and other reports concerning the 
work under this contract as the contracting officer may from time to 
time require.
    (f) Inspections. The DOE shall have the right to inspect the work 
and activities of the contractor under this contract at such time in 
such manner as it shall deem appropriate.
    (g) Subcontracts. The contractor further agrees to require the 
inclusion of provisions similar to those in paragraphs (a) through (g) 
and paragraph (i) of this clause in all subcontracts (including fixed-
price or unit-price subcontracts or purchase orders) of any tier entered 
into hereunder where, under the terms of the subcontract, costs incurred 
are a factor in determining the amount payable to the subcontractor.

    Note: If the prime contract contains a ``Defective Cost or Pricing 
Data'' clause, this paragraph (g) shall be modified by adding the 
following:
    The contractor further agrees to include an audit clause, the 
substance of which is the ``Audit'' clause set forth at FAR 52.215-22, 
in each subcontract which does not include provisions similar to those 
in paragraph (a) through this paragraph (g) of this clause, but which 
contains a ``defective cost or pricing data'' clause.

    (h) Internal audit. The contractor agrees to conduct an internal 
audit and examination satisfactory to DOE of the records, operations, 
expenses, and the transactions with respect to costs claimed to be 
allowable under this contract annually and at such other times as may be 
mutually agreed upon. The results of such audit, including the working 
papers, shall be submitted or made available to the contracting officer.

    Note: This paragraph (h) shall be included in (a) all cost-type 
contracts (or subcontracts) involving an estimated cost exceeding $5 
million and expected to run more than 2 years, and (b) any other cost-
type contract (or subcontract) where deemed advisable by the Head of the 
Contracting Activity and when the contractor (or subcontractor) already 
has an established internal audit organization.

    The contractor further agrees to include an ``Audit'' clause, the 
substance of which is the ``Audit'' clause set forth at FAR 52.215-2, in 
each subcontract which does not include provisions similar to those in 
paragraph (a) through paragraph (g) and paragraph (i) of this clause, 
but which contains a ``defective cost and pricing data'' clause.

    (i) Comptroller General. (1) The Comptroller General of the United 
States, or an authorized representative, shall have access to and the 
right to examine any of the contractor's directly pertinent records 
involving transactions related to this contract or a subcontract 
hereunder.
    (2) This paragraph may not be construed to require the contractor or 
subcontractor to create or maintain any record that the contractor or 
subcontractor does not maintain in the ordinary course of business or 
pursuant to a provision of law.
    (3) Nothing in this contract shall be deemed to preclude an audit by 
the General Accounting Office of any transaction under this contract.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994; 61 
FR 21977, May 13, 1996; 61 FR 30823, June 18, 1996]



970.5204-10  Foreign ownership, control, or influence over contractors (FOCI).

    (a) Insert the clause at 952.204-73 in a solicitation for a 
management and operating contract.
    (b) Insert the clause at 952.204-74 in management and operating 
contracts as prescribed at 970.0404-4.
[49 FR 12063, Mar. 28, 1984, as amended at 56 FR 41965, Aug. 26, 1991]



970.5204-11  Changes.

    Insert the following clause.

                           Changes (Apr 1984)

    (a) Changes and adjustment of fee. The contracting officer may at 
any time and without notice to the sureties, if any, issue written 
directions within the general scope of this contract requiring 
additional work or directing the omission of, or variation in, work

[[Page 465]]

covered by this contract. If any such direction results in a material 
change in the amount or character of the work described in the 
``Statement of Work,'' an equitable adjustment of the fee, if any, shall 
be made in accordance with the agreement of the parties and the contract 
shall be modified in writing accordingly. Any claim by the contractor 
for an adjustment under this clause must be asserted in writing within 
30 days from the date of receipt by the contractor of the notification 
of change; provided, however, that the contracting officer, if he 
decides that the facts justify such action, may receive and act upon any 
such claim asserted at any time prior to final payment under this 
contract. A failure to agree on an equitable adjustment under this 
clause shall be deemed to be a dispute within the meaning of the clause 
entitled ``Disputes.''
    (b) Work to continue. Nothing contained in this clause shall excuse 
the contractor from proceeding with the prosecution of the work in 
accordance with the requirements of any direction hereunder.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9110, Feb. 25, 1994]



970.5204-12  Contractor's organization.

    As prescribed in 970.2272(b)(2), insert the following clause.

                  Contractor's Organization (JUL 1994)

    (a) Organization chart. As promptly as possible after the execution 
of this Contract, the contractor shall furnish to the contracting 
officer a chart showing the names, duties, and organization of key 
personnel to be employed in connection with the work, and shall furnish 
from time to time supplementary information reflecting changes therein.
    (b) Supervisory representative of contractor. Unless otherwise 
directed by the contracting officer, a competent full-time resident 
supervisory representative of the contractor satisfactory to the 
contracting officer shall be in charge of the work at the site at all 
times. This also applies to off-site work.
    (c) Control of employees. The contractor shall be responsible for 
maintaining satisfactory standards of employee competency, conduct, and 
integrity and shall be responsible for taking such disciplinary action 
with respect to his employees as may be necessary. In the event the 
contractor fails to remove any employee from the contract work whom DOE 
deems incompetent, careless, or insubordinate, or whose continued 
employment on the work is deemed by DOE to be contrary to the public 
interest, the Government reserves the right to require the contractor to 
remove the employee.

    Note: The contracting officer may substitute the following paragraph 
for (c) above:

    (c) The contractor shall be responsible for maintaining satisfactory 
standards of employee competency, conduct, and integrity and shall be 
responsible for taking such disciplinary action with respect to its 
employees as may be necessary. The contractor shall establish such 
standards and procedures as are necessary to implement effectively the 
provisions set forth in 970.2272, and such standards and procedures 
shall be subject to the approval of the contracting officer.
[49 FR 12063, Mar. 28, 1984; 49 FR 38953, Oct. 2, 1984, as amended at 56 
FR 41965, Aug. 26, 1991; 59 FR 9110, Feb. 25, 1994; 59 FR 24359, May 11, 
1994; 62 FR 2313, Jan. 16, 1997]



970.5204-13  Allowable costs and fixed-fee (management and operating contracts).

    As prescribed in 48 CFR (DEAR) 970.3103(a), insert the following 
clause.

Allowable Costs and Fixed-Fee (Management and Operating Contracts) (June 
                                  1997)

    (a) Compensation for contractor's services. Payment for the 
allowable costs as hereinafter defined, and of the fixed-fee, if any, as 
hereinafter provided, shall constitute full and complete compensation 
for the performance of the work under this contract.
    (b) Fixed-fee. The fixed-fee payable to the contractor for the 
performance of the work under this contract is $______. There shall be 
no adjustment in the amount of the contractor's fixed-fee by reason of 
differences between any estimate of cost for performance of the work 
under this contract and the actual costs for performance of that work.

    Note: This provision to this paragraph may be appropriately changed 
to cover situations where the fee is for a period of time or different 
fees are allowed for various phases of the work.

    (c) Allowable costs. The allowable cost of performing the work under 
this contract shall be the costs and expenses that are actually incurred 
by the contractor in the performance of the contract work in accordance 
with its terms, that are necessary or incident thereto, and that are 
determined to be allowable as set forth in this paragraph. The 
determination of allowability of cost shall be based on:
    (1) Allowability and reasonableness in accordance with FAR 31.201-
2(d) and 31.201-3;
    (2) Standards promulgated by the Cost Accounting Standards Board, if 
applicable; otherwise, generally accepted accounting principles and 
practices appropriate to the particular circumstances; and
    (3) Recognition of all exclusions and limitations set forth in this 
clause or elsewhere in this contract as to types or amounts of

[[Page 466]]

items of cost. Allowable costs shall not include the cost of any item 
described as unallowable in paragraph (e) of this clause except as 
indicated therein. Failure to mention an item of cost specifically in 
paragraphs (d) or (e) of this clause shall not imply either that it is 
allowable or that it is unallowable.
    (d) Items of allowable cost. Subject to the other provisions of this 
clause, the following items of cost of work done under this contract 
shall be allowable to the extent indicated:
    (1) Bonds and insurance, including self-insurance, as provided in 
the clause entitled, Insurance--Litigation and Claims.
    (2) Communication costs, including telephone services, local and 
long-distance calls, telegrams, cablegrams, postage, and similar items.
    (3) Consulting services (including legal and accounting), and 
related expenses, as approved by the contracting officer, except as made 
unallowable by paragraphs (e)(16) and (e)(26).
    (4) Reasonable litigation and other legal expenses, including 
counsel fees, if incurred in accordance with the clause of the contract 
entitled, Insurance--Litigation and Claims, and the DOE approved 
contractor litigation management procedures (including cost guidelines) 
as such procedures may be revised from time to time, and if not 
otherwise made unallowable in this contract.
    (5) Losses and expenses (including settlements made with the consent 
of the contracting officer) sustained by the contractor in the 
performance of this contract and certified in writing by the contracting 
officer to be reasonable, except the losses and expenses expressly made 
unallowable under other provisions of this contract.
    (6) Materials, supplies, and equipment, including freight 
transportation, material handling, inspection, storage, salvage, and 
other usual expenses incident to the procurement, use and disposition 
thereof, subject to approvals required under other provisions of this 
contract.
    (7) Patents, purchased design, and royalty payments to the extent 
expressly provided for under other provisions in this contract or as 
approved by the contracting officer, and preparation of invention 
disclosures, reports and related documents, and searching the art to the 
extent necessary to make such invention disclosures in accordance with 
any ``Patent Rights'' clause of this contract.
    (8) Personnel costs and related expenses incurred in accordance with 
the personnel appendix which is hereby incorporated by reference and 
made a part of this contract. It is specifically understood and agreed 
that said personnel appendix sets forth in detail personnel costs and 
related expenses to be allowable under this contract and is intended to 
document those personnel policies, practices and plans which have been 
found acceptable by the contracting officer. It is further understood 
and agreed that the contractor will advise DOE of any proposed changes 
in any matters covered by said policies, practices or plans which relate 
to this item of cost, and that the personnel appendix may be modified 
from time to time in writing by mutual agreement of the contractor and 
DOE without execution of an amendment to this contract for the purpose 
of effectuating any such changes in, or additions to, said personnel 
appendix as may be agreed upon by the parties. Such modifications shall 
be evidenced by execution of written numbered approval letters from the 
contracting officer or his representative. Types of personnel costs and 
related expenses to be incorporated into the personnel appendix, or 
amendments thereto, are as follows:
    (i) Salaries and wages; bonuses and incentive compensation; 
overtime, shift differential, holiday, and other premium pay for time 
worked; nonwork time, including vacations, holidays, sick, funeral, 
military, jury, witness, and voting leave; salaries and wages to 
employees in their capacity as union stewards and committeemen for time 
spent in handling grievances, or serving on labor management 
(contractor) committees, provided, however, that the contracting 
officer's approval is required in each instance of total compensation to 
an individual employee at an annual rate of $______ (see 970.3102-2) or 
more, when it is proposed that a total of 50 percent or more of such 
compensation be reimbursed under DOE cost-type contracts. Total 
compensation, as used here, includes only the employee's base salary, 
bonus, and incentive compensation payments;
    (ii) Legally required contributions to old-age and survivors' 
insurance, unemployment compensation plans, and workers compensation 
plans, (whether or not covered by insurance); voluntary or agree-upon 
plans providing benefits for retirement, separation, life insurance, 
hospitalization, medical-surgical and unemployment (whether or not such 
plans are covered by insurance);
    (iii) Travel (except foreign travel, which requires specific 
approval by the contracting officer on a case-by-case basis); incidental 
subsistence and other allowances of contractor employees, in connection 
with performance of work under this contract (including new employees 
reporting for work and transfer of employees, the transfer of their 
household goods and effects and the travel and subsistence of their 
dependents);
    (iv) Employee relations, welfare, morale, etc.; programs including 
incentive or suggestion awards; employee counseling services, health or 
first-aid clinics; house or employee publications;
    (v) Personnel training (except special education and training 
courses and research assignments calling for attendance at educational 
institutions which require specific

[[Page 467]]

approval by the contracting officer on a case-by-case basis); including 
apprenticeship training programs designed to improve efficiency and 
productivity of contract operations, to develop needed skills, and to 
develop scientific and technical personnel in specialized fields 
required in the contract work;
    (vi) Recruitment of personnel (including help-wanted advertisement), 
including service of employment agencies at rates not in excess of 
standard commercial rates, employment office, travel of prospective 
employees at the request of the contractor for employment interviews; 
and
    (vii) Net cost of operating plant-site cafeteria, dining rooms, and 
canteens attributable to the performance of the contract.

    Note: In appropriate circumstances, the lead sentence in 
subparagraph (d)(8) may be changed to read as follows:

    ``Personnel costs and related expenses incurred in accordance with 
established policies, programs, and schedules, and any changes thereto 
during the contract term, applicable to the contractor's private 
operations and consistently followed throughout his organization, as 
approved by the contracting officer, such as''.
    (9) Repairs, maintenance, inspection, replacement, and disposal of 
Government-owned property and the restoration or clean-up of site and 
facilities to the extent approved by the contracting officer and as 
allowable under paragraph (f) of the clause of this contract entitled, 
Property.
    (10) Subcontracts and purchase orders, including procurements from 
contractor-controlled sources, subject to approvals required by other 
provisions of this contract.
    (11) Subscriptions to trade, business, technical, and professional 
periodicals, as approved by the contracting officer.
    (12) Taxes, fees, and charges levied by public agencies which the 
contractor is required by law to pay, except those which are expressly 
made unallowable under other provisions of this contract.
    (13) Utility services, including electricity, gas, water, and 
sewerage.
    (14) Indemnification of the Pension Benefit Guaranty Corporation, 
pursuant to the Employee Retirement Income Security Act of 1974, in 
accordance with FAR 31.205-6(j)(3)(iv).
    (15) Establishment and maintenance of bank accounts in connection 
with the work hereunder, including, but not limited to, service charges, 
the cost of disbursing cash, necessary guards, cashiers, and paymasters. 
If payments are made by check, facilities and arrangements for cashing 
checks may be provided without expense to the employees, subject to the 
approval of the contracting officer.

    Note: The following additional examples apply when the contractor 
performs construction.

    (16) Camp operations, to the extent approved by the contracting 
officer.
    (17) Maintenance, inspection, repair, replacement, and 
transportation of construction plant and equipment to the extent not 
covered by rentals or insurance and as provided in rental agreements 
approved by the contracting officer.
    (18) Rental for (i) construction plant and equipment rented by the 
contractor from others at rates and under written agreements approved by 
the contracting officer, and (ii) construction plant and equipment owned 
and furnished by the contractor under this contract.
    (e) Items of unallowable costs. The following items of costs are 
unallowable under this contract to the extent indicated:
    (1) Advertising and public relations costs designed to promote the 
contractor or its products, including the costs of promotional items and 
memorabilia such as models, gifts and souvenirs, and the cost of 
memberships in civic and community organizations; except those 
advertising and public relations costs
    (i) Specifically required by the contract,
    (ii) Approved in advance by the contracting officer as clearly in 
furtherance of work performed under the contract,
    (iii) That arise from requirements of the contract and that are 
exclusively for recruiting personnel, acquiring scarce items for 
contract performance, disposing of scrap or surplus materials, the 
transfer of federally owned or originated technology to State and local 
governments and to the private sector, or acquisition of contract-
required supplies and services, or
    (iv) Where the primary purpose of the activity is to facilitate 
contract performance in support of the DOE mission.
    (2) Bad debts (including expenses of collection) and provisions for 
bad debts arising out of other business of the contractor.
    (3) Proposal expenses and costs of proposals.
    (4) Bonuses and similar compensation under any other name, which (i) 
are not pursuant to an agreement between the contractor and employee 
prior to the rendering of the services or an established plan 
consistently followed by the contract or (ii) are in excess of those 
costs which are allowable by the Internal Revenue Code and regulations 
thereunder, or (iii) provide total compensation to an employee in excess 
of reasonable compensation for the services rendered.
    (5) Central and branch office expenses of the contractor, except as 
specifically set forth in the contract.

[[Page 468]]

    (6) Commissions, bonuses, and fees (under whatever name) in 
connection with obtaining or negotiating for a Government contract or a 
modification thereto, except when paid to bona fide employees or bona 
fide established selling organizations maintained by the contractor for 
the purpose of obtaining Government business.
    (7) Contingency reserves, provisions for.
    (8) Contributions and donations, including cash, contractor-owned 
property and services, regardless of the recipient.
    (9) Depreciation in excess of that calculated by application of 
methods approved for use by the Internal Revenue Code of 1954, as 
amended, including the straight-line declining balance (using a rate not 
exceeding twice the rate which would have been used had the depreciation 
been computed under the straight line method), or sum-of-the-years 
digits method, on the basis of expected useful life, to the cost of 
acquisition of the related fixed assets less estimated salvage or 
residual value at the end of the expected useful life.
    (10) Dividend provisions or payments and, in the case of sole 
proprietors and partners, distributions of profit.
    (11) Entertainment, including costs of amusement, diversion, social 
activities; and directly associated costs such as tickets to shows or 
sports events, meals, lodging, rentals, transportation, and gratuities; 
costs of membership in any social, dining or country club or 
organization, except the costs of such recreational activities for on-
site employees as may be approved by the contracting officer or provided 
for elsewhere in the contract.
    (12) Fines and penalties, except, with respect to civil fines and 
penalties only, if the contractor demonstrates to the contracting 
officer that--
    (i) Such a civil fine or penalty was incurred as a result of 
compliance with specific terms and conditions of the contract or written 
instructions from the contracting officer; or
    (ii) Such a civil fine or penalty was imposed without regard to 
fault and could not have been avoided by the exercise of due care.
    (13) Government-furnished property, except to the extent that cash 
payment therefor is required pursuant to procedures of DOE applicable to 
transfers of such property to the contractor from others.
    (14) Insurance (including any provisions of a self-insurance 
reserve) on any person where the contractor under the insurance policy 
is the beneficiary, directly or indirectly, and insurance against loss 
of or damage to Government property as defined in Clause ________.
    (15) Interest, however represented (except (i) Interest incurred in 
compliance with the contract clause entitled ``State and local Taxes'' 
or, (ii) imputed interest costs relating to leases classified and 
accounted for as capital leases under generally accepted accounting 
principles (GAAP), provided that the decision to enter into a capital 
leasing arrangement has been specifically authorized and approved by the 
DOE in accordance with applicable procedures and such interest costs are 
recorded in an appropriately specified DOE account established for such 
purpose), bond discounts and expenses, and costs of financing and 
refinancing operations.
    (16) Legal, accounting, and consulting services and related costs 
incurred in connection with the preparation and issuance of stock, 
rights, organization or reorganization, prosecution or defense of 
antitrust suits, prosecution of claims against the United States, 
contesting actions of proposed actions of the United States, and 
prosecution or defense of patent infringement litigation (except where 
incurred pursuant to the contractor's performance of the Government-
funded technology transfer mission and in accordance with the Litigation 
and Claims article).
    (17) Losses or expenses:
    (i) On, or arising from the sale, exchange, or abandonment of 
capital assets, including investments;
    (ii) On other contracts, including the contractor's contributed 
portion under cost-sharing contracts;
    (iii) In connection with price reductions to and discount purchases 
by employees and others from any source;
    (iv) That are compensated for by insurance or otherwise or which 
would have been compensated for by insurance required by law or by 
written direction of the contracting officer but which the contractor 
failed to procure or maintain through its own fault or negligence;
    (v) That result from willful misconduct or lack of good faith on the 
part of any of the contractor's managerial personnel (as that term is 
defined in the clause of this contract entitled, Property);
    (vi) That represent liabilities to third persons that are not 
allowable under the clause of this contract entitled, Insurance-- 
Litigation and Claims; or
    (vii) That represent liabilities to third persons for which the 
contractor has expressly accepted responsibility under other terms of 
this contract.
    (18) Maintenance, depreciation, and other costs incidental to the 
contractor's idle or excess facilities (including machinery and 
equipment), other than reasonable standby facilities.

    Note: May be omitted when no contractor-owned equipment is being 
utilized in the performance of the contract.

    (19) Membership in trade, business, and professional organizations, 
except as approved by the contracting officer.

[[Page 469]]

    (20) Precontract costs, except as expressly made allowable under 
other provisions in this contract.
    (21) Research and development costs, unless specifically provided 
for elsewhere in this contract.
    (22) Selling cost, except to the extent they are determined to be 
reasonable and to be allocable to the contract. Allocability of selling 
costs to the contract will be determined in the light of reasonable 
benefit to the agency program arising from such activities as technical, 
consulting, demonstration, and other services performed for such 
purposes as applying or adapting the contractor's product for agency 
use.
    (23) Storage of records pertaining to this contract after completion 
of operations under this contract, irrespective of contractual or 
statutory requirement for the preservation of records.
    (24) Taxes, fees, and charges in connection with financing, 
refinancing, or refunding operations, including listing of securities on 
exchanges, taxes which are paid contrary to the clause entitled ``State 
and local taxes,'' federal taxes on net income and excess profits, 
special assessments on land which represent capital improvement and 
taxes on accumulated funding deficiencies of, or prohibited transactions 
involving, employee deferred compensation plans pursuant to section 4971 
or section 4975 of the Internal Revenue Code of 1954, as amended, 
respectively.
    (25) Travel expenses of the officers, proprietors, executives, 
administrative heads and other employees of the contractor's central 
office or branch office organizations concerned with the general 
management, supervision, and conduct of the contractor's business as a 
whole, except to the extent that particular travel is in connection with 
the contract and approved by the contracting officer.
    (26) Salary or other compensation (and expenses related thereto) of 
any individual employed under this contract as a consultant or in 
another comparable employment capacity who is an employee of another 
organizational and concurrently performing work on a full-time annual 
basis for that organization under a cost-type contract with DOE, except 
to the extent that cash payment therefor is required pursuant to the 
provisions of this contract or procedure of DOE applicable to the 
borrowing of such an individual from another cost-type contractor.
    (27) Travel by commercial aircraft or travel by other than common 
carrier that is not necessary for the performance of this contract or 
the cost of which exceeds the lesser of the lowest available commercial 
discount airfare, Government contract airfare, or customary standard 
(coach or equivalent) commercial airfare. Airfare costs in excess of the 
lowest such airfare are unallowable, except when such accommodations: 
Require circuitous routing; require travel during unreasonable hours; 
excessively prolong travel; result in increased cost that would offset 
transportation savings; would offer accommodations not reasonably 
adequate for the physical or medical needs of the traveler; or are not 
reasonably available to meet necessary mission requirements. Individual 
contractor determinations of nonavailability of commercial discount 
airfare or Government contract airfare will not be contested by DOE when 
the contractor can reasonably demonstrate such nonavailability or, on an 
overall basis, that established policies and procedures result in the 
routine use of the lowest available airfare. However, in order for air 
travel costs in excess of customary standard airfare to be allowable, 
the contractor must justify and document the applicable condition(s) set 
forth above.
    (28) Special construction industry ``funds'' financed by employer 
contributions for such purposes as methods and materials research, 
public and industry relations, market development, and disaster relief, 
except as specifically provided elsewhere in this contract.
    (29) Late premium payment charges related to employee deferred 
compensation plan insurance.
    (30) Facilities capital cost of money. (CAS 414 and CAS 417).
    (31) Cost incurred to influence (directly or indirectly) legislative 
action on any matter pending before Congress or a State legislature as 
delineated in the clause titled ``Legislative Lobbying Cost 
Prohibition'' incorporated elsewhere in this contract.
    (32) Commercial automobile rental expenses unless approved by the 
contracting officer.
    (33) Costs incurred in connection with any criminal, civil or 
administrative proceeding commenced by the Federal Government or a 
State, local or foreign government, as provided in the clause titled 
``Cost prohibitions related to legal and other proceedings'' 
incorporated elsewhere in this contract.
    (34) Costs of alcoholic beverages.
    (35) Contractor employee travel costs incurred for lodging, meals 
and incidental expenses which exceed on a daily basis the applicable 
maximum per diem rates in effect for Federal civilian employees at the 
time of travel. When the applicable maximum per diem rate is inadequate 
due to special or unusual situations, the contractor may pay employees 
for actual expenses in excess of such per diem rate limitation. To be 
allowable, however, such payments must be properly authorized by an 
officer or appropriate official of the contractor and shall not exceed 
the higher amounts that may be authorized for Federal civilian employees 
in a similar situation.
    (36) Notwithstanding any other provision of this contract, the costs 
of bonds and insurance are unallowable to the extent they are

[[Page 470]]

incurred to protect and indemnify the contractor and/or subcontractor 
against otherwise unallowable costs, unless such insurance or bond is 
required by law, the express terms of this contract, or is authorized in 
writing by the contracting officer. The cost of commercial insurance to 
protect the contractor against the costs of correcting its own defects 
in materials or workmanship is an unallowable cost.
[49 FR 12063, Mar. 28, 1984; 49 FR 38953, Oct. 2, 1984, as amended at 51 
FR 43926, Dec. 5, 1986; 52 FR 1610, Jan. 14, 1987; 52 FR 38426, Oct. 16, 
1987; 53 FR 21648, June 9, 1988; 54 FR 27649, June 30, 1989; 55 FR 
41540, Oct. 12, 1990; 56 FR 28104, June 19, 1991; 56 FR 41966, Aug. 26, 
1991; 58 FR 61628, Nov. 22, 1993; 59 FR 9110, Feb. 25, 1994; 61 FR 
21977, May 13, 1996; 61 FR 30823, June 18, 1996; 62 FR 34866, June 27, 
1997]



970.5204-14  Allowable costs and fixed-fee (support contracts).

    As prescribed in 48 CFR (DEAR) 970.3103(a), insert the following 
clause.

      Allowable Costs and Fixed-Fee (Support Contracts) (June 1997)

    (a) Compensation for contractor's services. Payment for the 
allowable cost as hereinafter defined, and of the fixed-fee, if any, as 
hereinafter provided, shall constitute full and complete compensation 
for the performance of the work under this contract.
    (b) Fixed-fee. The fixed-fee payable to the contractor for the 
performance of the work under this contract is $    . There shall be no 
adjustment in the amount of the contractor's fixed-fee by reason of 
differences between any estimate of cost for performance of the work 
under this contract and the actual cost for performance of that work.

    Note: This provision to this paragraph may appropriately be changed 
to cover situations where the fee is for a period of time, or different 
fees are allowed for various phases of the work.

    (c) Allowable costs. The allowable cost of performing the work under 
this contract shall be the costs and expenses that are actually incurred 
by the contractor in the performance of the contract work in accordance 
with its terms, that are necessary or incident thereto, and are 
determined to be allowable as set forth in this paragraph. The 
determination of allowability of cost hereunder shall be based on:
    (1) Allowability and reasonableness in accordance with FAR 31.201-
2(d) and 31.201-3;
    (2) Standards promulgated by the Cost Accounting Standards Board, if 
applicable; otherwise, generally accepted accounting principles and 
practices appropriate to the particular circumstances; and
    (3) Recognition of all exclusions and limitations set forth in this 
clause or elsewhere in this contract as to types or amounts of items of 
cost. Allowable costs shall not include the cost of any item described 
as unallowable in paragraph (e) of this clause except as indicated 
therein. Failure to mention an item of cost specifically in paragraphs 
(d) or (e) of this clause shall not imply either that it is allowable or 
that it is unallowable.
    (d) Items of allowable cost. Subject to the other provisions of this 
clause, the following items of cost of work under this contract shall be 
allowable to the extent indicated:
    (1) Bonds and insurance, including self-insurance, as provided in 
the clause entitled Insurance--Litigation and Claims.
    (2) Communication costs, including telephone services, local and 
long-distance telephone calls, telegrams, cablegrams, radiograms, 
postage, and similar items.
    (3) Consulting services (including legal and accounting) and related 
expenses, as approved by the contracting officer, except as made 
unallowable by paragraph (e)(14) and (e)(23).
    (4) Reasonable litigation and other legal expenses, including 
counsel fees, if incurred in accordance with the clause of the contract 
entitled, Insurance--Litigation and Claims, in accordance with DOE 
approved contractor litigation management procedures (including cost 
guidelines) as such procedures may be revised from time to time, and if 
not otherwise made unallowable in this contract.
    (5) Losses and expenses (including settlements made with the consent 
of the contracting officer) sustained by the contractor in performance 
of this contract and certified in writing by the contracting officer to 
be just and reasonable, except the losses and expenses expressly made 
unallowable under other provisions of this contract.
    (6) Materials and supplies (including those withdrawn from common 
stores costed in accordance with any generally recognized method that is 
consistently applied by the contractor and productive of equitable 
results).
    (7) Patents, purchased design, and royalty payments to the extent 
expressly provided for under other provisions in this contract or as 
approved by the contracting officer; and preparation of invention 
disclosures, reports, and related documents, and searching the art to 
the extent necessary to make such invention disclosures in accordance 
with the Patent Rights clause of this contract.
    (8) Personnel costs and related expenses incurred in accordance with 
the personnel appendix which is hereby incorporated by reference and 
made a part of this contract. It is specifically understood and agreed 
that said personnel appendix sets forth, in detail, personnel costs and 
related expenses to be allowable under this contract and is intended

[[Page 471]]

to document those personnel policies, practices and plans which have 
been found acceptable by the contracting officer. It is further 
understood and agreed that the contractor will advise DOE of any 
proposed changes in any matters covered by said policies, practices, or 
plans which relate to this item of costs, and that the personnel 
appendix may be modified from time to time in writing by mutual 
agreement of the contractor and DOE without execution of an amendment to 
this contract for the purpose of effectuating and such changes in, or 
additions to, said personnel appendix, as may be agreed upon by the 
parties. Such modifications shall be evidenced by execution of written 
numbered approval letters from the contracting officer or his 
representative. Examples of personnel costs and related expenses to be 
incorporated into the personnel appendix, or amendments thereto, are as 
follows:
    (i) Salaries and wages; bonuses and incentive compensation; 
overtime, shift differential, holiday, and other premium pay for time 
worked; nonwork time including vacations, holidays, sick, funeral, 
military, jury, witness, and voting leave; salaries and wages to 
employees in their capacity as union stewards and committeemen for time 
spent in handling grievances, or serving on labor management 
(contractor) committees, provided, however, that the contracting 
officer's approval is required in each instance of total compensation to 
an individual employee at an annual rate of $________ (See 970.3102-2) 
or more, when it is proposed that a total of 50 percent or more of such 
compensation be reimbursed under DOE cost-type contracts. Total 
compensation, as used here, includes only the employee's base salary and 
bonus and incentive compensation payments.
    (ii) Legally required contributions to old-age and survivor's 
insurance, unemployment, compensation plans, and workmen's compensation 
plans (whether or not covered by insurance); voluntary or agreed-upon 
plans providing benefits for retirement, separation, life insurance, 
hospitalization, medical-surgical and unemployment (whether or not such 
plans are covered by insurance);
    (iii) Travel (except foreign-travel, which requires specific 
approval by the contracting officer on a case-by-case basis); incidental 
subsistence and other allowances of contractor employees, in connection 
with performance of work under this contract (including new employees 
reporting for work and transfer of employees, the transfer of their 
household goods and effects, and the travel and subsistence of their 
dependents);
    (iv) Employee relations, welfare, morale, etc., programs, including 
incentive or suggestion awards, employee counseling services, health or 
first-aid clinics, and house or employee publications;
    (v) Personnel training (except special education and training 
courses and research assignments calling for attendance at educational 
institutions which require specific approval by the contracting officer 
on a case-by-case basis) including services of employment agencies at 
rates not in excess of standard commercial rates, employment office, 
travel of prospective employees at the request of the contractor for 
employment interviews; and
    (vi) Recruitment of personnel (including help-wanted advertisement) 
including services of employment agencies at rates not in excess of 
standard commercial rates, employment office, travel of prospective 
employees at the request of the contractor for employment interviews; 
and
    (vii) Net cost of operating plant-site cafeterias, dining rooms, and 
canteens attributable to the performance of the contract.

    Note: In appropriate circumstances that lead sentence in 
subparagraph (d)(8) may be changed to read as follows:

    Personnel costs and related expenses incurred in accordance with 
established policies, programs, and schedules, and any changes thereto 
during the contract term, applicable to the contractor's private 
operations and consistently followed throughout its organization, as 
approved by the contracting officer, such as:
    (9) Rentals and leases of land, buildings, and equipment owned by 
third parties where such items are used in the performance of the 
contract, except that such rentals and leases directly chargeable to the 
contract shall be subject to approval by the contracting officer.
    (10) Repairs, maintenance, inspection, replacement, and disposal of 
government-owned property to the extent directed or approved by the 
contracting officer and as allowable under paragraph (f) of the clause 
of this contract entitled, Property.
    (11) Repairs, maintenance, and inspection of contractor owned 
property used in connection with the performance of this contract, 
including reasonable standby facilities, which are due to ordinary wear 
and tear from use and the action of the elements, provided such 
maintenance and repairs keep the property in efficient operating 
condition and do not add to its permanent value or appreciably prolong 
its intended useful life; and major repair (including replacement) to 
such property, as directed or approved by the contracting officer when 
charged directly to the contract.
    (12) Special tooling, including jigs, dies, fixtures, molds, 
patterns, designs and drawings, tools, and equipment of a specialized 
nature generally useful to the contractor only in the performance of 
this contract.

    Note: Itemize any additional special equipment which may be 
appropriate, such as loops, mockups, experimental setups, etc.


[[Page 472]]


    (13) Subcontracts, purchase orders, and procurement from contractor-
controlled sources, subject to approvals required by other provisions of 
this contract.
    (14) Subscriptions to trade, business, technical, and professional 
periodicals, as approved by the contracting officer when charged 
directly to the contract.
    (15) Taxes, fees, and charges levied by public agencies which the 
contractor is required by law to pay, except those which are expressly 
made unallowable under other provisions of this contract.
    (16) Utility services, including electricity, gas, water, steam, and 
sewerage.
    (17) Indemnification of the Pension Benefit Guaranty Corporation 
pursuant to the Employee Retirement Income Security Act of 1974, in 
accordance with FAR 31.205-6(j).
    (e) Items of unallowable costs. The following examples of items of 
costs are unallowable under this contract to the extent indicated:
    (1) Advertising and public relations costs designed to promote the 
contractor or its products, including the costs of promotional items and 
memorabilia such as models, gifts and souvenirs, and the cost of 
memberships in civic and community organizations; except those 
advertising and public relations costs (i) specifically required by the 
contract, (ii) approved in advance by the contracting officer as clearly 
in furtherance of work performed under the contract, (iii) that arise 
from requirements of the contract and that are exclusively for 
recruiting personnel, acquiring scarce items for contract performance 
disposing of scrap or surplus materials, the transfer of federally owned 
or originated technology to State and local governments and to the 
private sector, or acquisition of contract-required supplies and 
services, publicizing community involvement, or (iv) where the primary 
purpose of the activity is to facilitate contract performance in support 
of the DOE mission.
    (2) Bad debts (including expenses of collection) and provisions for 
bad debts not arising out of the performance of this contract.
    (3) Bonuses and similar compensation under any other name, which (i) 
are not pursuant to an agreement between the contractor and employee 
prior to the rendering of the services or an established plan 
consistently followed by the contractor (ii) are in excess of those 
costs which are allowable by the Internal Revenue Code and regulations 
thereunder, or (iii) provide total compensation to an employee in excess 
of reasonable compensation for the services rendered.
    (4) Commissions, bonuses, and fees (under whatever name) in 
connection with obtaining or negotiating for a Government contract or a 
modification thereto, except when paid to bona fide employees or bona 
fide established selling organizations maintained by the contractor for 
the purpose of obtaining Government business.
    (5) Contingency reserves, provisions for (except provisions for 
reserves under a self-insurance program to the extent that the type, 
coverage, rates, and premiums would be allowable if commercial insurance 
were purchased to cover the same risk, as approved by the contracting 
officer).
    (6) Contributions and donations, including cash, contractor-owned 
property and services, regardless of the recipient.
    (7) Depreciation in excess of that calculated by application of 
methods approved for use by the Internal Revenue Service under the 
Internal Revenue Code of 1954, as amended, including the straight-line 
declining balance (using a rate not exceeding twice the rate which would 
have been used had the depreciation been computed under the straight-
line method) or sum-of-the-years digits method, on the basis of expected 
useful life, to the cost of acquisition of the related fixed assets less 
estimated salvage or residual value at the end of the expected useful 
life. Amortization or depreciation of unrealized appreciation of values 
of assets or of assests fully amortized or depreciated on the 
contractors books of account is unallowable.
    (8) Dividend provisions or payments and, in the case of sole 
proprietors and partners, distributions of profits.
    (9) Entertainment, including costs of amusement, diversion, social 
activities; any directly associated costs such as tickets to shows or 
sports events, meals, lodging, rentals, transportation, and gratuities; 
costs of membership in any social, dining or country club or 
organization, except the costs of such recreational activities for on-
site employees as may be approved by the contracting officer or provided 
for elsewhere in the contract.
    (10) Fines and penalties, except, with respect to civil fines and 
penalties only, if the contractor demonstrates to the contracting 
officer that--
    (i) Such a civil fine or penalty was incurred as a result of 
compliance with specific terms and conditions of the contract or written 
instructions from the contracting officer; or
    (ii) Such a civil fine or penalty was imposed without regard to 
fault and could not have been avoided by the exercise of due care.
    (11) Government-furnished property, except to the extent that cash 
payment therefor is required pursuant to procedures of the DOE 
applicable to transfers of such property to the contractor from others.
    (12) Insurance (including and provision of a self-insurance reserve) 
on any person where the contractor under the insurance policy is the 
beneficiary, directly or indirectly, and insurance against loss or 
damage to Government property.
    (13) Interest, however represented (except (i) Interest incurred in 
compliance with the contract clause entitled ``State and local

[[Page 473]]

Taxes'' or, (ii) imputed interest costs relating to leases classified 
and accounted for as capital leases under generally accepted accounting 
principles (GAAP), provided that the decision to enter into a capital 
leasing arrangement has been specifically authorized and approved by the 
DOE in accordance with applicable procedures and such interest costs are 
recorded in an appropriately specified DOE account established for such 
purpose), bond discounts and expenses, and costs of financing and 
refinancing operations.
    (14) Legal, accounting, and consulting services, and related costs 
incurred in connection with the preparation of prospectuses, preparation 
and issuance of stock rights, organization or reorganization, 
prosecution or defense of antitrust suits, prosecution of claims against 
the United States, contesting actions or proposed actions of the United 
States, and prosecution or defense of patent infringement litigation.
    (15) Losses or expenses:
    (i) On, or arising from the sale, exchange, or abandonment of 
capital assets, including investments;
    (ii) On other contracts, including the contractor's contributed 
portion under cost-sharing contracts;
    (iii) In connection with price reductions to and discount purchases 
by employees and others from any source;
    (iv) That are compensated for by insurance or otherwise or which 
would have been compensated for by insurance required by law or by 
written direction of the contracting officer but which the contractor 
failed to procure or maintain through its own fault or negligence;
    (v) That result from willful misconduct or lack of good faith on the 
part of any of the contractor's managerial personnel (as that term is 
defined in the clause of this contract entitled, Property);
    (vi) That represent liabilities to third persons that are not 
allowable under the clause of this contract entitled, Insurance--
Litigation and Claims; or
    (vii) That represent liabilities to third persons for which the 
contractor has expressly accepted responsibility under other terms of 
this contract.
    (16) Maintenance, depreciation, and other costs incidental to the 
contractor's idle or excess facilities (including machinery and 
equipment) other than reasonable standby facilities.
    (17) Membership in trade, business, and professional organizations 
except as approved by the contracting officer.
    (18) Precontract costs, except as expressly made allowable under 
other provisions in this contract.
    (19) Reconversion, alteration, restoration, or rehabilitation of the 
contractor's facilities, except as expressly provided elsewhere in this 
contract.
    (20) Selling costs, except to the extent they are determined to be 
reasonable and to be allocable to the contract. Allocability of selling 
costs to the contract will be determined in the light of reasonable 
benefit to the agency program arising from such purposes as applying or 
adapting the contractor's product for agency use.
    (21) Storage or records pertaining to this contract after completion 
of operations under this contract irrespective of contract or statutory 
requirement for the preservation of records.
    (22) Taxes, fees, and charges in connection with financing, 
refinancing or refunding operations, including the listing of securities 
on exchanges; taxes which are paid contrary to the clause entitled 
``State and local taxes;'' Federal taxes on net income and excess 
profits; special assessments on land which represent capital improvement 
and taxes on accumulated funding deficiencies of, or prohibited 
transactions involving, employee deferred compensation plans pursuant to 
section 4971 or section 4975 of the Internal Revenue Code of 1954, as 
amended, respectively.
    (23) Salary or other compensation (and expenses related thereto) of 
any individual employed under this contract as a consultant or in 
another comparable employment capacity who is an employee of another 
organization and concurrently performing work on a full-time annual 
basis for that organization under a cost-type contract with DOE, except 
to the extent that cash payment thereto is required pursuant to the 
provisions of this contract or procedures of the DOE applicable to the 
borrowing of such an individual from another cost-type contractor.
    (24) Travel by commercial aircraft or travel by other than common 
carrier that is not necessary for the performance of this contract or 
the cost of which exceeds the lesser of the lowest available commercial 
discount airfare, Government contract airfare, or customary standard 
(coach or equivalent) commercial airfare. Airfare costs in excess of the 
lowest such airfare are unallowable, except when such accommodations: 
Require circuitous routing; require travel during unreasonable hours; 
excessively prolong travel; result in increased cost that would offset 
transportation savings; would offer accommodations not reasonably 
adequate for the physical or medical needs of the traveler; or are not 
reasonably available to meet necessary mission requirements. Individual 
contractor determinations of nonavailability of commercial discount 
airfare or Government contract airfare will not be contested by DOE when 
the contractor can reasonably demonstrate such nonavailability or, on an 
overall basis, that established policies and procedures result in the 
routine use of the lowest available airfare. However, in order for air 
travel costs in excess of customary standard airfare to be

[[Page 474]]

allowable, the contractor must justify and document the applicable 
condition(s) set forth above.
    (25) Late premium payment charges related to employee deferred 
compensation plan insurance, in accordance with FAR 31.205-6(j).
    (26) Research and development costs, unless specifically provided 
for elsewhere in this contract.
    (27) Bidding expenses and costs of proposals.
    (28) Facilities capital cost of money (CAS-414 and CAS-417).
    (29) Costs incurred to influence (directly or indirectly) 
legislative action on any matter pending before Congress or a State 
legislature as delineated in the clause titled ``Legislative Lobbying 
Cost Prohibition'' incorporated elsewhere in this contract.
    (30) Commercial automobile rental costs unless approved by the 
contracting officer.
    (31) Costs incurred in connection with any criminal, civil or 
administrative proceeding commenced by the Federal Government or a 
State, local or foreign government, as provided in the clause titled 
``Cost prohibitions related to legal and other proceedings'' 
incorporated elsewhere in this contract.
    (32) Costs of alcoholic beverages.
    (33) Contractor employee travel costs incurred for lodging, meals 
and incidental expenses which exceed on a daily basis the applicable 
maximum per diem rates in effect for Federal civilian employees at the 
time of travel. When the applicable maximum per diem rate is inadequate 
due to special or unusual situations, the contractor may pay employees 
for actual expenses in excess of such per diem rate limitation. To be 
allowable, however, such payments must be properly authorized by an 
officer or appropriate official of the contractor and shall not exceed 
the higher amounts that may be authorized for Federal civilian employees 
in a similar situation.
    (34) Notwithstanding any other provision of this contract, the costs 
of bonds and insurance are unallowable to the extent they are incurred 
to protect and indemnify the contractor and/or subcontractor against 
otherwise unallowable costs, unless such insurance or bond is required 
by law, the express terms of this contract, or is authorized in writing 
by the contracting officer. The cost of commercial insurance to protect 
the contractor against the costs of correcting its own defects in 
materials or workmanship is an unallowable cost.
[49 FR 12063, Mar. 28, 1984, as amended at 51 FR 43926, Dec. 5, 1986; 52 
FR 1610, Jan. 14, 1987; 53 FR 21649, June 9, 1988; 55 FR 41540, Oct. 12, 
1990; 56 FR 28105, June 19, 1991; 58 FR 61628, Nov. 22, 1993; 59 FR 
9110, Feb. 25, 1994; 61 FR 21978, May 13, 1996; 61 FR 30823, June 18, 
1996; 62 FR 34866, June 27, 1997]



970.5204-15  Obligation of funds.

    As prescribed in 970.1508(c), insert the following clause.

                     Obligation of Funds (APR 1994)

    (a) Obligation of funds. The amount presently obligated by the 
Government with respect to this contract is ________ dollars ($______). 
Such amount may be increased unilaterally by DOE by written notice to 
the contractor and may be increased or decreased by written agreement of 
the parties (whether or not by formal modification of this contract). 
Estimated revenues and receipts from others for work and services to be 
performed under this contract are not included in this amount ________ 
obligated with respect to this contract. Such revenues and receipts, to 
the extent actually received by the contractor shall be available and 
used for the payment of allowable costs as provided in the article 
entitled ``Payments and Advances.'' Nothing in this paragraph (a) is to 
be construed as authorizing the contractor to exceed limitations stated 
in financial plans established by DOE and furnished to the contractor 
from time to time under this contract.
    (b) Limitation on payment by the Government. Except as otherwise 
provided in this contract and except for costs which may be incurred by 
the contractor pursuant to the clause entitled ``Termination,'' or costs 
of claims allowable under the contract occurring after completion or 
termination and not released by the contractor at the time of financial 
settlement of the contract in accordance with the clause entitled 
``Payments and Advances,'' payment by the Government under this contract 
on account of allowable costs shall not, in the aggregate, exceed the 
amount obligated with respect to this contract, less the contractor's 
fixed fee. Unless expressly negated in this contract, payment on account 
of those costs excepted in the preceding sentence which are in excess of 
the amount obligated with respect to this contract shall be subject to 
the availability of (1) revenues and receipts deposited to the 
Government's account as provided in the clause entitled ``Payments and 
Advances,'' and (2) other funds which DOE may legally use for such 
purpose, provided DOE will use its best efforts to obtain the 
appropriation of funds for this purpose if not otherwise available.
    (c) Notices--Contractor excused from further performance. The 
contractor shall notify DOE in writing whenever the unexpended balance 
of funds (including revenues and receipts) available under paragraph (a) 
above, plus the contractor's best estimate of revenues and receipts to 
be received during the ____ day

[[Page 475]]

period hereinafter specified, is in the contractor's best judgment 
sufficient to continue contract operations at the programmed rate for 
only ____ days and to cover the contractor's unpaid fixed fee, and 
outstanding commitments and liabilities on account of costs allowable 
under the contract at the end of such period. Whenever the unexpended 
balance of funds (including revenues and receipts) available under 
paragraph (a) above, less the amount of the contractor's fixed fee then 
earned but not paid, is in the contractor's best judgment either 
sufficient only to liquidate outstanding commitments and liabilities on 
account of costs allowable under this contract or is equal to zero, the 
contractor shall immediately notify DOE and shall make no further 
commitments or expenditures (except to liquidate existing commitments 
and liabilities), and, unless the parties otherwise agree, the 
contractor shall be excused from further performance (except such 
performance as may become necessary in connection with termination by 
the Government) and the performance of all work hereunder will be deemed 
to have been terminated for the convenience of the Government in 
accordance with the provisions of the article entitled ``Termination.''
    (d) Financial plans; cost and commitment limitations. In addition to 
the limitations provided for elsewhere in this contract, DOE may, 
through financial plans or other directives issued to the contractor, 
establish controls on the costs to be incurred and commitments to be 
made in the performance of the contract work. Such plans and instruction 
may be amended or supplemented from time to time by DOE. The contractor 
hereby agrees to comply with the specific limitations (ceilings) on 
costs and commitments set forth in such plans and directives, to use its 
best efforts to comply with other requirements of such plans and 
directive, and to promptly notify DOE in writing, whenever it has reason 
to believe the authorized financial levels of costs and commitments will 
be exceeded or substantially underrun.

    Note: This paragraph (d) may be omitted in contracts which expressly 
or otherwise provided a contractual basis for equivalent controls in a 
separate article.

    (e) Government's right to terminate not affected. The giving of any 
notice under this clause shall not be construed to waive or impair any 
right of the Government to terminate the contract under the provisions 
of the article entitled ``Termination.''
[49 FR 12063, Mar. 28, 1984, as amended at 56 FR 41966, Aug. 26, 1991; 
58 FR 32308, June 9, 1993; 59 FR 9111, Feb. 25, 1994; 62 FR 2313, Jan. 
16, 1997]



970.5204-16  Payments and advances.

    As prescribed in 48 CFR (DEAR) 970.3270, insert the following 
clause.

                    Payments and Advances (June 1997)

    (a) Installments of fixed-fee. Ninety percent (90%) of the fixed-fee 
shall become due and payable in periodic installments in amounts based 
on the proportion of the work then completed, as determined by the 
contracting officer, and the balance upon completion and acceptance of 
all work under this contract. Fixed-fee payments shall be made by direct 
payment or withdrawn from funds advanced or available under this 
contract, as determined by the contracting officer. The contracting 
officer may offset against any such fee payment, the amounts owed to the 
Government by the contractor, including any amounts owed for disallowed 
costs under this contract. No fixed-fee payment may be withdrawn against 
the letter-of-credit without prior written approval of the contracting 
officer.

    Note 1: Where a separate fixed-fee is provided for a separate item 
of work, this subparagraph should be modified to permit payment of the 
entire fixed-fee upon completion of that item.

    Note 2: When award-fee provisions in this clause are used, in lieu 
of paragraph (a), use the following text:

    (a) Payment of Base Fee and Award Fee. The base fee, if any, is 
payable in equal monthly installments. Award fee pool amounts earned are 
payable following the issuance by the FDO of a Determination of Award 
Fee Pool Amount Earned, in accordance with the clause of this contract 
entitled, Award Fee: Base Fee and Award Fee. Base fee and award fee pool 
amount earned payments shall be made by direct payment or withdrawn from 
funds advanced or available under this contract, as determined by the 
contracting officer. The contracting officer may offset against any such 
fee payment, the amounts owed to the Government by the contractor, 
including any amounts owed for disallowed costs under this contract. No 
base fee or award fee pool amount earned payment may be withdrawn 
against the letter-of-credit without prior written approval of the 
contracting officer.
    (b) Payments on Account of Allowable Costs. The contracting officer 
and the contractor shall agree as to the extent to which payment for 
allowable costs or payments for other items specifically approved in 
writing by the contracting officer shall be made from advances of 
Government funds. When pension contributions are paid by the contractor 
to the retirement fund less frequently than quarterly, accrued costs 
therefor shall be excluded from costs for payment purposes until such 
costs are paid. If pension contribution are paid on a quarterly or more

[[Page 476]]

frequent basis, accrual therefor may be included in costs for payment 
purposes, provided that they are paid to the fund within 30 days after 
the close of the period covered. If payments are not made to the fund 
within such 30-day period, pension contribution costs shall be excluded 
from cost for payment purposes until payment has been made.
    (c) Special bank account--use. All advances of Government funds 
shall be withdrawn pursuant to a letter of credit in favor of the bank 
or, in the option of the Government, shall be made by check payable to 
the contractor, and shall be deposited only in the Special Bank Account 
referred to in the Agreement for Special Bank Account, which is attached 
hereto and incorporated into this contract as an appendix. The 
contractor shall likewise deposit in the Special Bank Account any other 
revenues received by the contractor in connection with the work under 
this contract. No part of the funds in the Special Bank Account shall be 
(1) mingled with any funds of the contractor or (2) used for a purpose 
other than that of making payments for costs allowable under this 
contract or payments for other items specifically approved in writing by 
the contracting officer. If the contracting officer shall at any time 
determine that the balance on such bank account exceeds the contractor's 
current needs, the contractor shall promptly make such disposition of 
the excess as the contracting officer may direct.
    (d) Title to funds advanced. Title to the unexpended balance of any 
funds advanced and of any bank account established pursuant to this 
clause shall remain in the Government and be superior to any claim or 
lien of the bank of deposit or others. It is understood that an advance 
to the contractor hereunder is not a loan to the contractor, and will 
not require the payment of interest by the contractor, and that the 
contractor acquires no right, title or interest in or to such advance 
other than the right to make expenditures therefrom, as provided in this 
clause.

    Note 3: The following paragraph (e) shall be included in management 
and operating contracts with integrated contractors.

    (e) Review and approval of costs incurred. The contractor shall 
prepare and submit annually as of September 30, a voucher for the total 
of net expenditures accrued (i.e., net costs incurred) for the period 
covered by the voucher, and DOE, after audit and appropriate adjustment, 
will approve such voucher. This approval by DOE will constitute an 
acknowledgment by DOE that the net costs incurred are allowable under 
the contract and that they have been recorded in the accounts maintained 
by the contractor in accordance with DOE accounting policies, but will 
not relieve the contractor of responsibility for DOE's assets in its 
care, for appropriate subsequent adjustments, or for errors later 
becoming known to DOE.

    Note 4: It should be omitted in contracts with nonintegrated 
contractors.

    (f) Financial settlement. The Government shall promptly pay to the 
contractor the unpaid balance of allowable costs and fixed fee upon 
termination of the work, expiration of the term of the contract, or 
completion of the work and its acceptance by the Government after (1) 
compliance by the contractor with DOE's patent clearance requirements, 
and (2) the furnishing by the contractor of:
    (i) An assignment of the contractor's rights to any refunds, 
rebates, allowances, accounts receivable, or other credits applicable to 
allowable costs under the contract;
    (ii) A closing financial statement;
    (iii) The accounting for Government-owned property required by the 
clause entitled ``Property;'' and
    (iv) A release discharging the Government, its officers, agents, and 
employees from all liabilities, obligations, and claims arising out of 
or under this contract subject only to the following exceptions:
    (A) Specified claims in stated amounts or in estimated amounts where 
the amounts are not susceptible to exact statement by the contractor;
    (B) Claims, together with reasonable expenses incidental thereto, 
based upon liabilities of the contractor to third parties arising out of 
the performance of this contract; provided that such claims are not 
known to the contractor on the date of the execution of the release; and 
provided further that the contractor gives notice of such claims in 
writing to the contracting officer promptly, but not more than one (1) 
year after the contractor's right of action first accrues. In addition, 
the contractor should provide prompt notice to the contracting officer 
of all potential claims under this clause, whether in litigation or not 
(see also Contract Clause ________, DEAR 970.5204-31, ``Litigation and 
Claims''); and
    (C) Claims for reimbursement of costs (other than expenses of the 
contractor by reason of any indemnification of the Government against 
patent liability), including reasonable expenses incidental thereto, 
incurred by the contractor under the provisions of this contract 
relating to patents.

In arriving at the amount due the contractor under this clause, there 
shall be deducted, any claim which the Government may have against the 
contractor in connection with this contract, and deductions due under 
the terms of this contract, and not otherwise recovered by or credited 
to the Government. The unliquidated balance of the Special Bank Account 
may be applied to the amount due and any balance shall be returned to 
the Government forthwith.

[[Page 477]]

    (g) Claims. Claims for credit against funds advanced for payment 
shall be accompanied by such supporting documents and justification as 
the contracting officer shall prescribe.
    (h) Discounts. The contractor shall take and afford the Government 
the advantage of all known and available cash and trade discounts, 
rebates, allowances, credits, salvage, and commissions unless the 
contracting officer finds that action is not in the best interest of the 
Government.
    (i) Revenues. All revenues other than the contractor's fixed fee or 
fees, if any, accruing to the contractor in connection with the work 
under this contract shall be Government property and shall be deposited 
in the Special Bank Account to be available for payment of allowable 
cost under this contract.
    (j) Direct payment of charges. The Government reserves the right, 
upon ten days written notice from the contracting officer to the 
contractor, to pay directly to the persons concerned, all amounts due 
which otherwise would be allowable under this contract. Any payment so 
made shall discharge the Government of all liability to the contractor 
therefor.
[49 FR 12063, Mar. 28, 1984, as amended at 54 FR 48614, Nov. 24, 1989; 
55 FR 31053, July 31, 1990; 56 FR 28106, June 19, 1991; 59 FR 9111, Feb. 
25, 1994; 62 FR 34867, June 27, 1997]



970.5204-17  Legislative lobbying cost prohibition.

    As prescribed in 970.3103(b), insert the following clause.

            Legislative Lobbying Cost Prohibition (JAN 1996)

    (a) Pursuant to the allowable cost provisions established elsewhere 
under the contract, costs associated with the following activities are 
not reimbursable under the contract:
    (1) Attempts to influence the outcome of any Federal, State, or 
local election, referendum, initiative, or similar procedure, through 
in-kind or cash contributions, endorsements, publicity, or similar 
activities;
    (2) Establishing, administering, contributing to, or paying the 
expenses of a political party, campaign, political action committee, or 
other organization established for the purpose of influencing the 
outcomes of elections;
    (3) Any attempt to influence (i) the introduction of Federal or 
State legislation, or (ii) the enactment or modification of any pending 
Federal or State legislation through communication with any member or 
employee of the Congress or State legislature (including efforts to 
influence state or local officials to engage in similar lobbying 
activity), or with any government official or employee in connection 
with a decision to sign or veto enrolled legislation;
    (4) Any attempt to influence (i) the introduction of Federal or 
State legislation, or (ii) the enactment or modification of any pending 
Federal or State legislation by preparing, distributing or using 
publicity or propaganda, or by urging members of the general public or 
any segment thereof to contribute to or participate in any mass 
demonstration, march, rally, fund raising drive, lobbying campaign or 
letter writing or telephone campaign; or
    (5) Legislative liaison activities, including attendance at 
legislative sessions or committee hearings, gathering information 
regarding legislation, and analyzing the effect of legislation, when 
such activities are carried on in support of or in knowing preparation 
for an effort to engage in unallowable activities.
    (b) Costs of the following activities are excepted from the coverage 
of paragraph (a) of this clause; provided that the resultant contract 
costs are reasonable and otherwise comply with the allowable cost 
provisions of the contract:
    (1) Providing Members of Congress, their staff members, or staff of 
cognizant legislative committees, in response to a request (written or 
oral, prior or contemporaneous) from Members of Congress, their staff 
members, or staff of cognizant legislative committees, or as otherwise 
directed by the Contracting Officer, information or expert advice of a 
factual, technical, or scientific nature, with respect to topics 
directly related to the performance of the contract or proposed 
legislation. In providing this information or expert advice, the 
contractor shall indicate to the recipient that it is not presenting the 
views of DOE. Reasonable costs for transportation, lodging, or meals 
incurred by contractor employees for the purpose of providing such 
information or advice shall also be reimbursable, provided the request 
for information or expert advice is a prior written request signed by a 
Member of Congress, and provided such costs also comply with the 
allowable cost provisions of the contract.
    (2) Providing State legislatures or subdivisions thereof, their 
staff members, or staff of cognizant legislative committees, in response 
to a prior written request from a State legislator, or as otherwise 
directed by the Contracting Officer, information or expert advice of a 
factual, technical, or scientific nature, with respect to topics 
directly related to the performance of the contract or proposed 
legislation. In providing this information or expert advice, the 
contractor shall indicate to the recipient that it is not presenting the 
views of DOE. Reasonable costs for transportation, lodging, or meals 
incurred by contractor employees shall also be

[[Page 478]]

reimbursable, provided such costs also comply with the allowable costs 
provision of the contract.
    (3) Any lobbying made unallowable under paragraph (a)(3) of this 
clause to influence State legislation in order to directly reduce 
contract cost, or to avoid material impairment of the contractor's 
authority to perform the contract if authorized by the contracting 
officer.
    (4) Any activity specifically authorized by statute to be undertaken 
with funds from the contract.
    (c) Unallowable lobbying costs incurred, if any, shall not be 
charged to DOE, paid for with DOE funds or recorded as allowable cost in 
DOE's system of accounts.
    (d) The contractor's annual certification, submitted as part of its 
annual claim (i.e., Voucher Accounting for Net Expenditures Accrued 
required under the clause titled ``Payments and Advances'') or cost 
incurred statement, that the costs claimed are allowable under the 
contract, shall also serve as the contractor's certification that the 
requirements and standards of this clause have been complied with.
    (e) The contractor shall maintain adequate records to demonstrate 
that the annual certifications of claimed costs as being allowable 
comply with the requirements of this clause.
    (f) Time logs, calendars, or similar records shall not be created 
for purposes of complying with this clause during any particular 
calendar month when: (1) An employee engages in legislative liaison 
activities (as delineated in paragraphs (a) and (b) of this clause) 25 
percent or less of the employees's compensated hours of employment 
during that calendar month, and (2) within the preceding five-year 
period, the contractor has not materially misstated allowable or 
unallowable costs of any nature, including legislative liaison costs. 
When conditions (f)(1) and (2) of this clause are met, the contractor is 
not required to establish records to support the allowability of claimed 
costs in addition to records already required or maintained. Also, when 
conditions (f) (1) and (2) of this clause are met, the absence of time 
logs, calendars, or similar records will not serve as a basis for 
disallowing costs by contesting estimates of legislative liaison 
activity time spent by employees during any calendar month.
    (g) During contract performance, the contractor should resolve, in 
advance, any significant questions or disagreements between the 
contractor and DOE concerning compliance with this clause.
    (h) In providing information or expert advice under paragraphs 
(b)(1) and (b)(2) of this clause, the contractor shall advise the 
Contracting Officer in advance or as soon as practicable.
[53 FR 21649, June 9, 1988; 53 FR 24830, June 30, 1988, as amended at 59 
FR 9111, Feb. 25, 1994; 60 FR 63647, Dec. 12, 1995; 62 FR 2313, Jan. 16, 
1997]



970.5204-18  [Reserved]



970.5204-19  Printing clause for management and operating contracts.

    As prescribed in 970.5101, insert the following clause.

                           Printing (Apr 1984)

    (a) To the extent that duplicating or printing services may be 
required in the performance of this contract, the Contractor shall 
provide or secure such services in accordance with the Government 
Printing and Binding Regulations, Title 44 of the U.S. Code, and DOE 
Directives relative thereto.
    (b) The term Printing includes the following processes: composition, 
platemaking, presswork, binding, microform publishing, or the end items 
produced by such processes. Provided, however, that performance of a 
requirement under this contract involving the duplication of less than 
5,000 copies of a single page, or no more than 25,000 units in the 
aggregate of multiple pages, will not be deemed to be printing.
    (c) Printing services not obtained in compliance with this guidance 
shall result in the cost of such printing being disallowed.
    (d) In all subcontracts hereunder which require printing (as that 
term is defined in Title I of the U.S. Government Printing and Binding 
Regulations), the Contractor shall include a provision substantially the 
same as this clause.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9111, Feb. 25, 1994]



970.5204-20  Management controls.

    In accordance with 970.0901, the following clause shall be used in 
management and operating contracts:

                     Management Controls (AUG 1993)

    (a) The contractor shall be responsible for maintaining, as an 
integral part of its organization, effective systems of management 
controls for both administrative and programmatic functions. Management 
controls comprise the plan of organization, methods and procedures 
adopted by management to reasonably ensure that: The mission and 
functions assigned to the contractor are properly executed; efficient 
and effective operations are promoted; resources are safeguarded against 
theft, fraud, waste, and unauthorized use; all obligations and costs 
that

[[Page 479]]

are incurred under the contract are in compliance with applicable 
clauses and other current terms, conditions, and intended purposes; all 
revenues, expenditures, and all other transactions and assets are 
properly recorded, managed, and reported; and financial, statistical, 
and other reports necessary to maintain accountability and managerial 
control are accurate, reliable, and timely. The systems of controls 
employed by the contractor shall be documented and satisfactory to DOE. 
Such systems shall be an integral part of the contractor's management 
functions, including defining specific roles and responsibilities for 
each level of management, and holding employees accountable for the 
adequacy of the management systems and internal controls in their areas 
of assigned responsibility. The contractor shall, as part of the 
internal audit program required elsewhere in this contract, periodically 
review the management systems and internal controls employed in programs 
and administrative areas to ensure that they are adequate to provide 
reasonable assurance that the objectives of the system are being 
accomplished and that these systems and controls are working 
effectively.
    (b) The contractor shall be responsible for maintaining, as a part 
of its operational responsibilities, a baseline quality assurance 
program that implements documented performance, quality standards, and 
control and assessment techniques.
[56 FR 65448, Dec. 17, 1991, as amended at 58 FR 36365, July 7, 1993; 62 
FR 2313, Jan. 16, 1997]



970.5204-21  Property.

    As prescribed in 970.4501, insert the following clause.

                          Property (June 1997)

    (a) Furnishing of Government property. The Government reserves the 
right to furnish any property or services required for the performance 
of the work under this contract.
    (b) Title to property. Except as otherwise provided by the 
contracting officer, title to all materials, equipment, supplies, and 
tangible personal property of every kind and description purchased by 
the contractor, for the cost of which the contractor is entitled to be 
reimbursed as a direct item of cost under this contract, shall pass 
directly from the vendor to the Government. The Government reserves the 
right to inspect, and to accept or reject, any item of such property. 
The contractor shall make such disposition of rejected items as the 
contracting officer shall direct. Title to other property, the cost of 
which is reimbursable to the contractor under this contract, shall pass 
to and vest in the Government upon (1) issuance for use of such property 
in the performance of this contract, or (2) commencement of processing 
or use of such property in the performance of this contract, or (3) 
reimbursement of the cost thereof by the Government, whichever first 
occurs. Property furnished by the Government and property purchased or 
furnished by the contractor, title to which vests in the Government, 
under this paragraph are hereinafter referred to as Government property. 
Title to Government property shall not be affected by the incorporation 
of the property into or the attachment of it to any property not owned 
by the Government, nor shall such Government property or any part 
thereof, be or become a fixture or lose its identity as personalty by 
reason of affixation to any realty.
    (c) Identification. To the extent directed by the contracting 
officer, the contractor shall identify Government property coming into 
the contractor's possession or custody, by marking and segregating in 
such a way, satisfactory to the contracting officer, as shall indicate 
its ownership by the Government.
    (d) Disposition. The contractor shall make such disposition of 
Government property which has come into the possession or custody of the 
contractor under this contract as the contracting officer may direct 
during the progress of the work or upon completion or termination of 
this contract. The contractor may, upon such terms and conditions as the 
contracting officer may approve, sell, or exchange such property, or 
acquire such property at a price agreed upon by the Contracting Officer 
and the contractor as the fair value thereof. The amount received by the 
contractor as the result of any disposition, or the agreed fair value of 
any such property acquired by the contractor, shall be applied in 
reduction of costs allowable under this contract or shall be otherwise 
credited to account to the Government, as the contracting officer may 
direct. Upon completion of the work or the termination of this contract, 
the contractor shall render an accounting, as prescribed by the 
contracting officer, of all government property which had come into the 
possession or custody of the contractor under this contract.
    (e) Protection of government property--management of high-risk 
property and classified materials.
    (1) The contractor shall take all reasonable precautions, and such 
other actions as may be directed by the contracting officer, or in the 
absence of such direction, in accordance with sound business practice, 
to safeguard and protect government property in the contractor's 
possession or custody.
    (2) In addition, the contractor shall ensure that adequate 
safeguards are in place, and adhered to, for the handling, control and 
disposition of high-risk property and classified materials throughout 
the life cycle of the property and materials consistent with the

[[Page 480]]

policies, practices and procedures for property management contained in 
the Federal Property Management Regulations (41 CFR chapter 101), the 
Department of Energy Property Management Regulations (41 CFR chapter 
109), and other applicable regulations.
    (3) High-risk property is property, the loss, destruction, damage 
to, or the unintended or premature transfer of which could pose risks to 
the public, the environment, or the national security interests of the 
United States. High-risk property includes proliferation sensitive, 
nuclear related dual use, export controlled, chemically or radioactively 
contaminated, hazardous, and specially designed and prepared property, 
including property on the militarily critical technologies list.
    (f) Risk of loss of Government property.
    (1)(i) The contractor shall not be liable for the loss or 
destruction of, or damage to, Government property unless such loss, 
destruction, or damage was caused by any of the following:
    (A) Willful misconduct or lack of good faith on the part of the 
contractor's managerial personnel;
    (B) Failure of the contractor's managerial personnel to take all 
reasonable steps to comply with any appropriate written direction of the 
contracting officer to safeguard such property under paragraph (e) of 
this clause; or
    (C) Failure of contractor managerial personnel to establish, 
administer, or properly maintain an approved property management system 
in accordance with paragraph (i)(1) of this clause.
    (ii) If, after an initial review of the facts, the contracting 
officer informs the contractor that there is reason to believe that the 
loss, destruction of, or damage to the government property results from 
conduct falling within one of the categories set forth above, the burden 
of proof shall be upon the contractor to show that the contractor should 
not be required to compensate the government for the loss, destruction, 
or damage.
    (2) In the event that the contractor is determined liable for the 
loss, destruction or damage to Government property in accordance with 
(f)(1) of this clause, the contractor's compensation to the Government 
shall be determined as follows:
    (i) For damaged property, the compensation shall be the cost of 
repairing such damaged property, plus any costs incurred for temporary 
replacement of the damaged property. However, the value of repair costs 
shall not exceed the fair market value of the damaged property. If a 
fair market value of the property does not exist, the contracting 
officer shall determine the value of such property, consistent with all 
relevant facts and circumstances.
    (ii) For destroyed or lost property, the compensation shall be the 
fair market value of such property at the time of such loss or 
destruction, plus any costs incurred for temporary replacement and costs 
associated with the disposition of destroyed property. If a fair market 
value of the property does not exist, the contracting officer shall 
determine the value of such property, consistent with all relevant facts 
and circumstances.
    (3) The portion of the cost of insurance obtained by the contractor 
that is allocable to coverage of risks of loss referred to in paragraph 
(f)(1) of this clause is not allowable.
    (g) Steps to be taken in event of loss. In the event of any damage, 
destruction, or loss to Government property in the possession or custody 
of the contractor with a value above the threshold set out in the 
contractor's approved property management system, the contractor:
    (1) Shall immediately inform the contracting officer of the occasion 
and extent thereof,
    (2) Shall take all reasonable steps to protect the property 
remaining, and
    (3) Shall repair or replace the damaged, destroyed, or lost property 
in accordance with the written direction of the contracting officer. The 
contractor shall take no action prejudicial to the right of the 
Government to recover therefore, and shall furnish to the Government, on 
request, all reasonable assistance in obtaining recovery.
    (h) Government property for Government use only. Government property 
shall be used only for the performance of this contract.
    (i) Property Management.
    (1) Property Management System.
    (i) The contractor shall establish, administer, and properly 
maintain an approved property management system of accounting for and 
control, utilization, maintenance, repair, protection, preservation, and 
disposition of Government property in its possession under the contract. 
The contractor's property management system shall be submitted to the 
contracting officer for approval and shall be maintained and 
administered in accordance with sound business practice, applicable 
Federal Property Management Regulations and Department of Energy 
Property Management Regulations, and such directives or instructions 
which the contracting officer may from time to time prescribe.
    (ii) In order for a property management system to be approved, it 
must provide for:
    (A) Comprehensive coverage of property from the requirement 
identification, through its life cycle, to final disposition;
    (B) Employee personal responsibility and accountability for 
Government-owned property;
    (C) Full integration with the contractor's other administrative and 
financial systems; and

[[Page 481]]

    (D) A method for continuously improving property management 
practices through the identification of best practices established by 
``best in class'' performers.
    (iii) Approval of the contractor's property management system shall 
be contingent upon the completion of the baseline inventory as provided 
in subparagraph (i)(2) of this clause.
    (2) Property Inventory.
    (i) Unless otherwise directed by the contracting officer, the 
contractor shall within six months after execution of the contract 
provide a baseline inventory covering all items of Government property.
    (ii) If the contractor is succeeding another contractor in the 
performance of this contract, the contractor shall conduct a joint 
reconciliation of the property inventory with the predecessor 
contractor. The contractor agrees to participate in a joint 
reconciliation of the property inventory at the completion of this 
contract. This information will be used to provide a baseline for the 
succeeding contract as well as information for closeout of the 
predecessor contract.
    (j) The term ``contractor's managerial personnel'' as used in this 
clause means the contractor's directors, officers and any of its 
managers, superintendents, or other equivalent representatives who have 
supervision or direction of:
    (1) All or substantially all of the contractor's business; or
    (2) All or substantially all of the contractor's operations at any 
one facility or separate location to which this contract is being 
performed; or
    (3) A separate and complete major industrial operation in connection 
with the performance of this contract; or
    (4) A separate and complete major construction, alteration, or 
repair operation in connection with performance of this contract; or
    (5) A separate and discrete major task or operation in connection 
with the performance of this contract.


    Note:  Substitute the following paragraph (j) for nonprofit 
contractors:


    (j) The term ``contractor's managerial personnel'' as used in this 
clause means the contractor's directors, officers and any of its 
managers, superintendents, or other equivalent representatives who have 
supervision or direction of all or substantially all of:
    (1) The contractor's business; or
    (2) The contractor's operations at any one facility or separate 
location at which this contract is being performed; or
    (3) The contractor's Government property system and/or a Major 
System Acquisition or Major Project as defined in DOE Order 4700.1 
(Version in effect on effective date of contract).
    (k) The contractor shall include this clause in cost reimbursable 
contracts.
[49 FR 12063, Mar. 28, 1984; 49 FR 38953, Oct. 2, 1984, as amended at 56 
FR 28106, June 19, 1991; 59 FR 9111, Feb. 25, 1994; 60 FR 49516, Sept. 
26, 1995; 62 FR 34867, June 27, 1997]



970.5204-22  Contractor purchasing system.

    Insert the following clause.

                 Contractor Purchasing System (Oct 1995)

    (a) General. The contractor shall develop, implement, and maintain 
formal policies, practices, and procedures to be used in the award of 
subcontracts consistent with this clause, 48 CFR (DEAR) 970.5204-44, and 
48 CFR (DEAR) 970.71. The contractor's purchasing system and methods 
shall be fully documented, consistently applied, and acceptable to DOE 
in accordance with 48 CFR (DEAR) 970.7102. The contractor shall maintain 
file documentation which is appropriate to the value of the purchase and 
is adequate to establish the propriety of the transaction and the price 
paid. The contractor's purchasing performance will be evaluated against 
such performance criteria and measures as may be set forth elsewhere in 
this contract. DOE reserves the right at any time to require that the 
contractor submit for approval any or all purchases under this contract. 
The contractor shall not purchase any item or service the purchase of 
which is expressly prohibited by the written direction of DOE and shall 
use such special and directed sources as may be expressly required by 
the DOE contracting officer. The contractor's approved purchasing system 
and methods shall include the requirements set forth in paragraphs (b) 
through (w) of this clause.
    (b) Acquisition of Utility Services. Utility services shall be 
acquired in accordance with the requirements of 48 CFR (DEAR) 970.0803.
    (c) Acquisition of Real Property. Real property shall be acquired in 
accordance with 48 CFR (DEAR) subpart 917.74.
    (d) Advance Notice of Proposed Subcontract Awards. Advance notice 
shall be provided in accordance with 48 CFR (DEAR) 970.7109.
    (e) Audit of Subcontractors. (1) The contractor shall provide for:
    (i) periodic post-award audit of cost-reimbursement subcontractors 
at all tiers, and
    (ii) audits, where necessary, to provide a valid basis for pre-award 
or cost or price analysis.
    (2) Responsibility for determining the costs allowable under each 
cost-reimbursement subcontract remains with the contractor or next 
higher-tier subcontractor. The contractor shall provide, in appropriate 
cases, for the timely involvement of the contractor and the DOE 
contracting officer in resolution of subcontract cost allowability.

[[Page 482]]

    (3) Where audits of subcontractors at any tier are required, 
arrangements may be made to have the cognizant Federal agency perform 
the audit of the subcontract. These arrangements shall be made 
administratively between DOE and the other agency involved and shall 
provide for the cognizant agency to audit in an appropriate manner in 
light of the magnitude and nature of the subcontract. In no case, 
however, shall these arrangements preclude determination by the DOE 
contracting officer of the allowability or unallowability of 
subcontractor costs claimed for reimbursement by the contractor.
    (4) Allowable costs for cost reimbursable subcontracts are to be 
determined in accordance with the cost principles of FAR Part 31, 
appropriate for the type of organization to which the subcontract is to 
be awarded, as supplemented by 48 CFR (DEAR) part 931. Allowable costs 
in the purchase or transfer from contractor-affiliated sources shall be 
determined in accordance with 48 CFR (DEAR) 970.7105 and 48 CFR (DEAR) 
970.3102-15(b).
    (f) Bonds and Insurance. (1) The contractor shall require 
performance bonds in penal amounts as set forth in FAR 28.102-2(a) for 
all fixed priced and unit-priced construction subcontracts in excess of 
$25,000. The contractor shall consider the use of performance bonds in 
fixed price nonconstruction subcontracts, where appropriate.
    (2) A payment bond shall be obtained on Standard Form 25A, modified 
to name the contractor as well as the United States of America as 
obligees, for all fixed price, unit-price and cost-reimbursement 
construction subcontractors in excess of $25,000. The penal amounts 
shall be determined as set forth in FAR 28.102-2(b).
    (3) A subcontractor may have more than one acceptable surety in both 
construction and other subcontracts, provided that in no case will the 
liability of any one surety exceed the maximum penal sum for which it is 
qualified for any one obligation. For subcontracts other than 
construction, a co-surety (two or more sureties together) may reinsure 
amounts in excess of their individual capacity, with each surety having 
the required underwriting capacity that appears on the list of 
acceptable corporate sureties.
    (g) Buy American. The contractor shall comply with the provisions of 
the Buy American Act as reflected in 48 CFR (DEAR) 970.5203-3 and 48 CFR 
(DEAR) 970.5204-3. The contractor shall forward determinations of 
nonavailability of individual items to the DOE contracting officer for 
approval. Items in excess of $100,000 require the prior concurrence of 
the Head of Contracting Activity. If, however, the contractor has an 
approved purchasing system, the Head of the Contracting Activity may 
authorize the contractor to make determinations of nonavailability for 
individual items valued at $100,000 or less.
    (h) Construction and Architect-Engineer Subcontracts. (1) 
Independent Estimates. A detailed, independent estimate of costs shall 
be prepared for all construction work to be subcontracted.
    (2) Specifications. Specifications for construction shall be 
prepared in accordance with the DOE publication entitled ``General 
Design Criteria Manual.''
    (3) Prevention of Conflict of Interest. (i) The contractor shall not 
award a subcontract for construction to the architect-engineer firm or 
an affiliate that prepared the design. This prohibition does not 
preclude the award of a ``turnkey'' subcontract so long as the 
subcontractor assumes all liability for defects in design and 
construction and consequential damages.
    (ii) The contractor shall not award both a cost-reimbursement 
subcontract and a fixed-price subcontract for construction or architect-
engineer services or any combination thereof to the same firm where 
those subcontracts will be performed at the same site.
    (iii) The contractor shall not employ the construction subcontractor 
or an affiliate to inspect the firm's work. The contractor shall assure 
that the working relationships of the construction subcontractor and the 
subcontractor inspecting its work and the authority of the inspector are 
clearly defined.
    (i) Contractor-Affiliated Sources. Equipment, materials, supplies, 
or services from a contractor-affiliated source shall be purchased or 
transferred in accordance with 48 CFR (DEAR) 970.7105.
    (j) Contractor-Subcontractor Relationship. The obligations of the 
contractor under paragraph (a) of this clause, including the development 
of the purchasing system and methods, and purchases made pursuant 
thereto, shall not relieve the contractor of any obligation under this 
contract (including, among other things, the obligation to properly 
supervise, administer, and coordinate the work of subcontractors). 
Subcontracts shall be in the name of the contractor, and shall not bind 
or purport to bind the Government.
    (k) Government Property. Identification, inspection, maintenance, 
protection, and disposition of Government property shall conform with 
the policies and principles of FAR Part 45, 48 CFR (DEAR) 945, the 
Federal Property Management Regulations 41 CFR 101, the DOE Property 
Management Regulations 41 CFR 109, and their contracts.
    (l) Indemnification. Except for Price-Anderson Nuclear Hazards 
Indemnity, no subcontractor may be indemnified except with the prior 
approval of the Procurement Executive.
    (m) Leasing of Motor Vehicles. Contractors shall comply with FAR 
8.11 and 48 CFR (DEAR) 908.11.

[[Page 483]]

    (n) Make-or-Buy Plans. Acquisition of property and services shall be 
obtained on a least-cost basis, consistent with the requirements of the 
Make-or-Buy Plan clause of this contract and the contractor's approved 
make-or-buy plan.
    (o) Management, Acquisition and Use of Information Resources. 
Requirements for automatic data processing resources and 
telecommunications facilities, services, and equipment, shall be 
reviewed and approved in accordance with applicable DOE Orders and 
regulations regarding information resources.
    (p) Priorities, Allocations and Allotments. Priorities, allocations 
and allotments shall be extended to appropriate subcontracts in 
accordance with the clause or clauses of this contract dealing with 
priorities and allocations.
    (q) Purchase of Special Items. Purchase of the following items shall 
be in accordance with the following provisions of 48 CFR (DEAR) 908.71 
and the Federal Property Management Regulations, 41 CFR 101:
    (1) Motor vehicles--48 CFR 908.7101
    (2) Aircraft--48 CFR 908.7102
    (3) Security Cabinets--48 CFR 908.7106
    (4) Alcohol--48 CFR 908.7107
    (5) Helium--48 CFR 908.7108
    (6) Fuels and packaged petroleum products--48 CFR 908.7109
    (7) Coal--48 CFR 908.7110
    (8) Arms and Ammunition--48 CFR 908.7111
    (9) Heavy Water--48 CFR 908.7121(a)
    (10) Precious Metals--48 CFR 908.7121(b)
    (11) Lithium--48 CFR 908.7121(c)
    (12) Products and services of the blind and severely handicapped--41 
CFR 101-26.701
    (13) Products made in Federal penal and correctional institutions--
41 CFR 101-26.702
    (r) Purchase vs. Lease Determinations. Contractors shall determine 
whether required equipment and property should be purchased or leased, 
and establish appropriate thresholds for application of lease vs. 
purchase determinations. Such determinations shall be made:
    (1) at time of original acquisition;
    (2) when lease renewals are being considered; and
    (3) at other times as circumstances warrant.
    (s) Quality Assurance. Contractors shall provide no less protection 
for the Government in its subcontracts than is provided in the prime 
contract.
    (t) Setoff of Assigned Subcontractor Proceeds. Where a subcontractor 
has been permitted to assign payments to a financial institution, the 
assignment shall treat any right of setoff in accordance with 48 CFR 
(DEAR) 932.803.
    (u) Strategic and Critical Materials. The contractor may use 
strategic and critical materials in the National Defense Stockpile.
    (v) Termination. When subcontracts are terminated as a result of the 
termination of all or a portion of this contract, the contractor shall 
settle with subcontractors in conformity with the policies and 
principles relating to settlement of prime contracts in FAR subparts 
49.1, 49.2 and 49.3. When subcontracts are terminated for reasons other 
than termination of this contract, the contractor shall settle such 
subcontracts in general conformity with the policies and principles in 
FAR subparts 49.1, 49.2, 49.3 and 49.4. Each such termination shall be 
documented and consistent with the terms of this contract. Terminations 
which require approval by the Government shall be supported by 
accounting data and other information as may be directed by the 
contracting officer.
    (w) Unclassified Controlled Nuclear Information. Subcontracts 
involving unclassified uncontrolled nuclear information shall be treated 
in accordance with 10 CFR part 1017.
[60 FR 49516, Sept. 26, 1995]



970.5204-23  Taxes.

    As prescribed in 970.2903, insert the following clause.

                    State and Local Taxes (Apr 1984)

    (a) The contractor agrees to notify the contracting officer of any 
State or local tax, fee, or charge levied or purported to be levied on 
or collected from the contractor with respect to the contract work, any 
transaction thereunder, or property in the custody or control of the 
contractor and constituting an allowable item of cost if due and 
payable, but which the contractor has reason to believe, or the 
contracting officer has advised the contractor, is or may be 
inapplicable or invalid;* and the contractor further agrees to refrain 
from paying any such tax, fee, or charge unless authorized in writing by 
the Contracting Officer. Any State or local tax, fee, or charge paid 
with the approval of the contracting officer or on the basis of advice 
from the contracting officer that such tax, fee, or charge is applicable 
and valid, and which would otherwise be an allowable item of cost, shall 
not be disallowed as an item of cost by reason of any subsequent ruling 
or determination that such tax, fee, or charge was in fact inapplicable 
or invalid.

    *Requirement for notice may be broadened to include all State and 
local taxes which may be claimed as allowable costs when considered to 
be appropriate.

    (b) The contractor agrees to take such action as may be required or 
approved by the contracting officer to cause any State or local tax, 
fee, or charge which would be an allowable cost to be paid under 
protest; and to take such action as may be required or approved by the 
contracting officer to seek recovery of any payments made, including 
assignment to the Government or its designee

[[Page 484]]

of all rights to an abatement or refund thereof, and granting permission 
for the Government to join with the contractor in any proceedings for 
the recovery thereof or to sue for recovery in the name of the 
contractor. If the contracting officer directs the contractor to 
institute litigation to enjoin the collection of or to recover payment 
of any such tax, fee, or charge referred to above, or if a claim or suit 
is filed against the contractor for a tax, fee, or charge it has 
refrained from paying in accordance with this article, the procedures 
and requirements of the article entitled ``Litigation and Claims'' shall 
apply and the costs and expenses incurred by the contractor shall be 
allowable items of costs, as provided in this contract, together with 
the amount of any judgment rendered against the contractor.
    (c) The Government shall hold the contractor harmless from penalties 
and interest incurred through compliance with this clause. All 
recoveries or credits in respect of the foregoing taxes, fees, and 
charges (including interest) shall inure to and be for the sole benefit 
of the Government.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9111, Feb. 25, 1994; 62 
FR 2313, Jan. 16, 1997]



970.5204-24  Subcontractor cost or pricing data.

    As prescribed in 970.7104-11, insert the following clause.

              Subcontractor Cost or Pricing Data (OCT 1995)

    (a) The following clause shall be inserted in all subcontracts where 
such subcontracts, and any modifications thereto, exceed the cost or 
pricing data threshold at FAR 15.804-2(a)(1), even though the original 
amount of the subcontract was below the threshold.

                Certified Cost or Pricing Data (Apr 1984)

    (a)(1) The subcontractor shall require under the situations 
described in (2) below, unless exempted under the exceptions set forth 
in (3) below, each sub-subcontractor under this subcontract to submit 
cost or pricing data and to certify that, to the best of his knowledge 
and belief, such cost or pricing data are accurate, complete and 
current.
    (2) Except as provided in (a)(3) of this clause, certified cost or 
pricing data shall be submitted prior to (i) award of each sub-
subcontract, the price of which is expected to exceed the cost or 
pricing data threshold at FAR 15.804-2(a)(1), and (ii) the negotiation 
of the price of each change or modification to the sub-subcontract under 
this subcontract for which the price adjustment is expected to exceed 
the cost or pricing data threshold at FAR 15.804-2(a)(1).
    (3) Certified cost or pricing data need not be furnished pursuant to 
this paragraph (a) where (i) the subcontractor has not been required to 
furnish cost or pricing data; or (ii) the price adjustment is based on 
adequate price competition, established catalog or market prices of 
commercial items sold in substantial quantities to the general public, 
or the prices are set by law or regulation; and the subcontractor states 
in writing the basis for applying this exception.
    (4) In submitting the cost or pricing data, the sub-subcontractor 
shall use the form of certificate set forth in paragraph (b) of this 
section and shall certify that the data are accurate, complete, and 
current. Such certificate and data (actual or identified, as provided in 
the certificate prescribed below) shall be submitted by sub-
subcontractors to the next higher-tier sub-subcontractor or the 
subcontractor, as applicable, for retention.
    (b) The certificates required by this clause shall be in the form 
set forth below.

       Subcontractor's Certificate of Current Cost or Pricing Data

    This is to certify that, to the best of my knowledge and belief, 
cost or pricing data submitted in writing, or specifically identified in 
writing if actual submission of the data is impracticable (see FAR 
15.804-6(d)), to the contractor in support of ____________* are 
accurate, complete, and current as of __________**.
 Firm___________________________________________________________________
 Name___________________________________________________________________
 Title__________________________________________________________________
 Date of execution***___________________________________________________
    *Identify the proposal, quotation, request for price adjustment, or 
other submission involved.
    **Insert the day, month, and year when price negotiations were 
concluded and price agreement was reached.
    ***Insert the day, month, and year of signing, which should be as 
close as practicable to the date when the price negotiations were 
concluded and the contract price was agreed to.

    (c) For purposes of verifying that certified cost or pricing data 
submitted in conjunction with the negotiation of this subcontract change 
or other modification involving an amount in excess of the cost or 
pricing data threshold at FAR 15.804-2(a)(1) were accurate, complete, 
and current, DOE shall, until the expiration of 3 years from the date of 
final payment under this subcontract, have the right to examine those 
books, records, documents, papers, and other supporting data which 
involve transactions related to this subcontract or which will permit 
adequate evaluation of the cost or pricing data submitted, along with 
the computations and projections used therein.

[[Page 485]]

    (d) If the original price of this subcontract exceeds the cost or 
pricing data threshold at FAR 15.804-2(a)(1) or the price of any change 
or other modification to this subcontract is expected to exceed the cost 
or pricing data threshold at FAR 15.804-2(a)(1), the subcontractor 
agrees to furnish the contractor certified cost or pricing data, using 
the certificate set forth in paragraph (b) of this clause, unless the 
price is based on adequate price competition, established catalog or 
market prices of commercial items sold in substantial quantities to the 
general public, or prices set by law or regulation.
    (e) The requirement for submission of certified cost or pricing data 
with respect to any change or other modification does not apply to any 
sub-subcontract change or other modification, at any tier, where the 
subcontract is firm fixed-price or fixed-price with escalation unless 
such change or other modification result from a change or modification 
to the subcontract, nor does it apply to a sub-subcontract change or 
modification, at any tier, where the subcontract is not firm fixed-price 
or fixed-price with escalation unless the price for such change or other 
modification becomes reimbursable under the subcontract.
    (f) The subcontractor agrees to insert paragraph (c) of this clause, 
without change, and the substance of paragraphs (a), (b), (d), (e), and 
(f) of this clause in each sub-subcontract hereunder in excess of the 
cost or pricing data threshold at FAR 15.804-2(a)(1) and in each sub-
subcontract that is less than the threshold when making a change or 
other modification thereto in excess of the cost or pricing data 
threshold at FAR 15.804-2(a)(1).
    (g) If the prime contractor determines that any price, including 
profit or fee, negotiated in connection with this subcontract or any 
cost reimbursable under this subcontract was increased by any 
significant sum because the subcontractor or any sub-subcontractor, 
pursuant to this clause or any sub-subcontract clause herein required, 
furnished incomplete or inaccurate cost or pricing data or data not 
current as certified in the subcontractor's certificate of current cost 
or pricing data, then such price or cost shall be reduced accordingly 
and the contract shall be modified in writing to reflect such reduction.
    (h) Failure of the contractor and the subcontractor to agree on any 
of the matters in paragraph (g) of this section shall be a dispute 
concerning a question of fact subject to the Disputes provisions of this 
subcontract.

    Note: Since the subcontract is subject to reduction under this 
clause by reason of defective cost or pricing data submitted in 
connection with certain sub-subcontracts, it is expected that the 
subcontractor may wish to include a clause in each such sub-subcontract 
requiring the sub-subcontractor to appropriately indemnify the 
subcontractor. It is also expected that any sub-subcontractor subject to 
such indemnification will generally require substantially similar 
indemnification for defective cost or pricing data required to be 
submitted by its lower-tier sub-subcontractors.

    (b) This clause may also be used for subcontracts in which the 
amount of the subcontract is less than the cost or pricing data 
threshold at FAR 15.804-2(a)(1), if a certificate of cost or pricing 
data is obtained; if so used, the amount stated in the clause should be 
modified appropriately.
    (c) The Head of the Contracting Activity, for contracts estimated to 
be within the limits of delegated authority, may, without power of 
redelegation, approve the waiver cited in FAR 15.804-3(i).
[49 FR 12063, Mar. 28, 1984; 49 FR 38953, Oct. 2, 1984, as amended at 50 
FR 12185, Mar. 27, 1985; 59 FR 9111, Feb. 25, 1994; 60 FR 18032, Apr. 
10, 1995; 60 FR 49517, Sept. 26, 1995; 62 FR 2313, Jan. 16, 1997]



970.5204-25  Workmanship and materials.

    Insert the following clause.

                  Workmanship and materials (Apr 1984)

    (a) Grade of workmanship and materials. Unless otherwise directed by 
the contracting officer or expressly provided for by specifications 
issued under this contract:
    (1) All workmanship shall be first class; and
    (2) All articles, equipment and materials incorporated in the work 
are to be:
    (i) New and of the most suitable grade of their respective kinds for 
the purpose;
    (ii) In accordance with any applicable drawings and specifications; 
and
    (iii) Installed to the satisfaction and with the approval of the 
contracting officer.

Where equipment, materials, or articles are referred to in the 
specifications as ``equal to'' any particular standard, the contracting 
officer shall decide the question of equality.
    (b) Samples and test results. If the contracting officer so 
requires, the contractor shall submit for approval samples of or test 
results on any materials proposed to be incorporated in the work before 
making any commitment for the purchase of such materials.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9111, Feb. 25, 1994]



970.5204-26  [Reserved]



970.5204-27  Consultant or other comparable employment services of contractor employees.

    (a) The following clause shall be included in all cost-reimbursement 
type contracts identified in 970.2272(b)(3).

[[Page 486]]

      Consultant or Other Comparable Employment Services (Apr 1984)

    The contractor shall require all employees who are employed full-
time (an individual who performs work under the cost-type contract on a 
full-time annual basis) or part-time (50 percent or more of regular 
annual compensation received under terms of a contract with DOE) on the 
contract work to disclose to the contractor all consultant or other 
comparable employment services which the employees propose to undertake 
for others. The contractor shall transmit to the contracting officer all 
information obtained from such disclosures. The contractor will require 
any employee who will be employed full-time on the contract o agree, as 
a condition of his participation in such work, that he will not perform 
consultant or other comparable employment services for another DOE 
contractor under its contract with DOE, except with the prior approval 
of the contractor.

    (b) The following clause shall be included in all contracts 
identified in 970.2272(b)(4).

      Consultant or Other Comparable Employment Services (May 1989)

    The contractor shall require all employees who are employed full-
time (an individual who performs work under the cost-type contract on a 
full-time annual basis) or part-time (50 percent or more of regular 
annual compensation received under terms of a contract with DOE) on the 
contract work to disclose to the contractor all consultant or other 
comparable employment services which the employees propose to undertake 
for others. The contractor shall transmit to the contracting officer all 
information obtained from such disclosures. The contractor will require 
any employee who will be employed full-time on the contract work to 
agree, as a condition of his participation in such work, that he will 
not perform consultant or other comparable employment services for 
another DOE contractor in the same or related energy field or another 
organization except with the prior approval of the contractor. If the 
contractor believes, with respect to any employee who is employed full-
time on the contract work, that any proposed consultant or other 
comparable employment service may involve: (1) A rate of remuneration 
significantly in excess of the employee's regular rate of remuneration; 
(2) a significant question concerning possible conflict with DOE's 
policies regarding conduct of employees of DOE's contractors; (3) the 
contractor's responsibility to report fully and promptly to DOE all 
significant research and development information; or (4) the patent 
provisions of the contractor's contract with DOE, the contractor shall 
obtain the prior approval of the contracting officer for such consultant 
or other comparable employment service.
[49 FR 12063, Mar. 28, 1984; 49 FR 38953, Oct. 2, 1984; 54 FR 27649, 
June 30, 1989]



970.5204-28  Assignment.

    Insert the following clause.

                          Assignment (Apr 1984)

    Neither this contract nor any interest therein nor claim thereunder 
shall be assigned or transferred by the contractor except as expressly 
authorized in writing by the contracting officer.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9111, Feb. 25, 1994]



970.5204-29  Permits or licenses.

    Insert the following clause.

                     Permits or Licenses (Apr 1984)

    Except as otherwise directed by the contracting officer, the 
contractor shall procure all necessary permits or licenses and abide by 
all applicable laws, regulations, and ordinances of the United States 
and of the state, territory, and political subdivision in which the work 
under this contract is performed.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9111, Feb. 25, 1994]



970.5204-30  Notice of labor disputes.

    As prescribed in 970.2201(b)(5)(ii), insert the clause at (FAR) 48 
CFR 52.222-1.
[59 FR 9111, Feb. 25, 1994]



970.5204-31  Insurance--litigation and claims.

    As prescribed in 48 CFR (DEAR) 970.2830(a), insert the following 
clause.

              Insurance--Litigation and Claims (June 1997)

    (a) The contractor may, with the prior written authorization of the 
contracting officer, and shall, upon the request of the Government, 
initiate litigation against third parties, including proceedings before 
administrative agencies, in connection with this contract. The 
contractor shall proceed with such litigation in good faith and as 
directed from time to time by the contracting officer.
    (b) The contractor shall give the contracting officer immediate 
notice in writing of any legal proceeding, including any proceeding 
before an administrative agency, filed against the contractor arising 
out of the performance of this contract. Except as otherwise directed by 
the contracting officer, in writing, the contractor shall furnish 
immediately to the contracting officer copies of

[[Page 487]]

all pertinent papers received by the contractor with respect to such 
action. The contractor, with the prior written authorization of the 
contracting officer, shall proceed with such litigation in good faith 
and as directed from time to time by the contracting officer.
    (c)(1) Except as provided in paragraph (c)(2) of this clause, the 
contractor shall procure and maintain such bonds and insurance as 
required by law or approved in writing by the contracting officer.
    (2) The contractor may, with the approval of the contracting 
officer, maintain a self-insurance program; provided that, with respect 
to workers' compensation, the contractor is qualified pursuant to 
statutory authority.
    (3) All bonds and insurance required by this clause shall be in a 
form and amount and for those periods as the contracting officer may 
require or approve and with sureties and insurers approved by the 
contracting officer.
    (d) The contractor agrees to submit for the contracting officer's 
approval, to the extent and in the manner required by the contracting 
officer, any other bonds and insurance that are maintained by the 
contractor in connection with the performance of this contract and for 
which the contractor seeks reimbursement. If an insurance cost (whether 
a premium for commercial insurance or related to self-insurance) 
includes a portion covering costs made unallowable elsewhere in the 
contract, and the share of the cost for coverage for the unallowable 
cost is determinable, the portion of the cost that is otherwise an 
allowable cost under this contract is reimbursable to the extent 
determined by the contracting officer.
    (e) Except as provided in subparagraphs (g) and (h) of this clause, 
or specifically disallowed elsewhere in this contract, the contractor 
shall be reimbursed--
    (1) For that portion of the reasonable cost of bonds and insurance 
allocable to this contract required in accordance with contract terms or 
approved under this clause, and
    (2) For liabilities (and reasonable expenses incidental to such 
liabilities, including litigation costs) to third persons not 
compensated by insurance or otherwise without regard to and as an 
exception to the clause of this contract entitled, Obligation of Funds 
(48 CFR (DEAR) 970.5204-15).
    (f) The Government's liability under paragraph (e) of this clause is 
subject to the availability of appropriated funds. Nothing in this 
contract shall be construed as implying that the Congress will, at a 
later date, appropriate funds sufficient to meet deficiencies.
    (g) Notwithstanding any other provision of this contract, the 
contractor shall not be reimbursed for liabilities (and expenses 
incidental to such liabilities, including litigation costs, counsel 
fees, judgment and settlements)--
    (1) Which are otherwise unallowable by law or the provisions of this 
contract; or
    (2) For which the contractor has failed to insure or to maintain 
insurance as required by law, this contract, or by the written direction 
of the contracting officer.
    (h) In addition to the cost reimbursement limitations contained in 
DEAR 970.3101-3, and notwithstanding any other provision of this 
contract, the contractor's liabilities to third persons, including 
employees but excluding costs incidental to workers' compensation 
actions, (and any expenses incidental to such liabilities, including 
litigation costs, counsel fees, judgments and settlements) shall not be 
reimbursed if such liabilities were caused by contractor managerial 
personnel's
    (1) Willful misconduct,
    (2) Lack of good faith, or
    (3) Failure to exercise prudent business judgment, which means 
failure to act in the same manner as a prudent person in the conduct of 
competitive business; or, in the case of a non-profit educational 
institution, failure to act in the manner that a prudent person would 
under the circumstances prevailing at the time the decision to incur the 
cost is made.
    (i) The burden of proof shall be upon the contractor to establish 
that costs covered by paragraph (h) of this clause are allowable and 
reasonable if, after an initial review of the facts, the contracting 
officer challenges a specific cost or informs the contractor that there 
is reason to believe that the cost results from willful misconduct, lack 
of good faith, or failure to exercise prudent business judgment by 
contractor managerial personnel.
    (j)(1) All litigation costs, including counsel fees, judgments and 
settlements shall be differentiated and accounted for by the contractor 
so as to be separately identifiable. If the contracting officer 
provisionally disallows such costs, then the contractor may not use 
funds advanced by DOE under the contract to finance the litigation.
    (2) Punitive damages are not allowable unless the act or failure to 
act which gave rise to the liability resulted from compliance with 
specific terms and conditions of the contract or written instructions 
from the contracting officer.
    (3) The portion of the cost of insurance obtained by the contractor 
that is allocable to coverage of liabilities referred to in paragraph 
(g)(1) of this clause is not allowable.
    (4) The term ``contractor's managerial personnel'' is defined in 
clause paragraph (j) of 48 CFR (DEAR) 970.5204-21.
    (k) The contractor may at its own expense and not as an allowable 
cost procure for its own protection insurance to compensate the 
contractor for any unallowable or unreimbursable costs incurred in 
connection with contract performance.

[[Page 488]]

    (l) If any suit or action is filed or any claim is made against the 
contractor, the cost and expense of which may be reimbursable to the 
contractor under this contract, and the risk of which is then uninsured 
or is insured for less than the amount claimed, the contractor shall--
    (1) Immediately notify the contracting officer and promptly furnish 
copies of all pertinent papers received;
    (2) Authorize Department representatives to collaborate with: in-
house or DOE-approved outside counsel in settling or defending the 
claim; or counsel for the insurance carrier in settling or defending the 
claim if the amount of the liability claimed exceeds the amount of 
coverage, unless precluded by the terms of the insurance contract; and
    (3) Authorize Department representatives to settle the claim or to 
defend or represent the contractor in and/or to take charge of any 
litigation, if required by the Department, if the liability is not 
insured or covered by bond. In any action against more than one 
Department contractor, the Department may require the contractor to be 
represented by common counsel. Counsel for the contractor may, at the 
contractor's own expense, be associated with the Department 
representatives in any such claim or litigation.
[62 FR 34868, June 27, 1997]



970.5204-32  [Reserved]



970.5204-33  Priorities and allocations.

    (a) The following clause shall be used in management and operating 
contracts for military and atomic energy construction, operations and 
other directly related activity, where the programs have been authorized 
pursuant to the Atomic Energy Act of 1954, as amended.

                  Priorities and Allocations (APR 1994)

    The contractor shall follow the rules and procedures of the Defense 
Priorities and Allocations System (DPAS) regulation (15 CFR part 700) in 
obtaining controlled materials and other products and materials needed 
for contract performance.
    (b) The following clause shall be used in management and operating 
contracts in support of programs and projects which may be determined to 
maximize domestic energy supplies.

     Priorities and Allocations--Domestic Energy Supplies (APR 1994)

    A program or project under this contract may be determined to be 
eligible for priorities and allocations support as provided for by 
section 101(c) of the Defense Production Act of 1950, as amended by the 
Energy Policy and Conservation Act (Pub. L. 94-163, 42 U.S.C. 6201 et 
seq.) if it is determined that its purpose is to maximize domestic 
energy supplies. Eligibility is dependent on an executive decision on a 
case-by-case basis with the decision being jointly made by the 
Department of Energy and Commerce.
    DOE regulations regarding material allocation and priority 
performance under contracts or orders to maximize domestic energy 
supplies can be found at part 216 of Title 10 of the Code of Federal 
Regulations (10 CFR part 216).

Additional guidance is provided by DOE Publication MA-0192, ``Priorities 
and Allocations Support for Energy: Keeping Energy Programs on 
Schedule,'' dated August 1985, as it may from time to time be revised. 
Copies may be obtained by written request to: Department of Energy, 
Office of Scientific and Technical Information (OSTI), Post Office Box 
62, Oak Ridge, Tennessee 37830.
[52 FR 38426, Oct. 16, 1987, as amended at 59 FR 9111, Feb. 25, 1994; 62 
FR 2313, Jan. 16, 1997]



970.5204-35  Controls in the national interest.

    Insert the following clause in contracts with educational 
institutions involving unclassified work.

              Controls in the National Interest (JUL 1994)

    The contractor agrees to comply with the requirements of DOE 1240.2 
(see current version.), Unclassified Visits and Assignments by Foreign 
Nationals, and to such other DOE requirements of the same general nature 
as the parties may agree to from time to time; these requirements relate 
to unclassified work, and they shall not be construed to limit or affect 
in any way the contractor's obligation to conform to all security 
regulations and requirements of DOE pertaining to classified work.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9111, Feb. 25, 1994; 59 
FR 24359, May 11, 1994; 62 FR 2313, Jan. 16, 1997]



970.5204-36  Preventing conflicts of interest in university research.

    Insert the following clause in contracts with universities where DOE 
has major investments in facilities but does not own or lease the land.

   Preventing Conflicts of Interest in University Research (Dec 1994)

    The parties agree that the university has adopted policies and 
procedures, designed to avoid conflict-of-interest situations, which

[[Page 489]]

are in substantial conformance with the Joint Statement of the Council 
of American Association of University Professors and the American 
Council on Education of December 1964, entitled, ``On Preventing 
Conflicts of Interest in Government-Sponsored Research at 
Universities,'' which policies and procedures will be applied in 
connection with this contract.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9111, Feb. 25, 1994; 59 
FR 66267, Dec. 23, 1994]



970.5204-37  Statement of work (management and operating contracts).

    See 970.1002.
[59 FR 9111, Feb. 25, 1994]



970.5204-38  Special clause for procurement of construction.

    As perscribed in 970.1002(c) and 970.3601 insert the following 
clause in management and operating contracts when the contractor is to 
perform no Davis-Bacon work with his own forces but may procure 
construction by subcontract:

           Government Facility Subcontract Approval (Apr 1994)

    Upon request of the contracting officer and acceptance thereof by 
the contractor, the contractor shall procure, by subcontract, the 
construction of new facilities or the alteration or repair of 
Government-owned facilities at the plant. Any subcontract entered into 
under this paragraph shall be subject to the written approval of the 
contracting officer and shall contain the provisions relative to labor 
and wages required by law to be included in contracts for the 
construction, alteration, and/or repair, including painting and 
decorating, of a public building or public work.
[49 FR 12063, Mar. 28, 1984; 49 FR 38953, Oct. 2, 1984, as amended at 59 
FR 9111, Feb. 25, 1994; 62 FR 2313, Jan. 16, 1997]



970.5204-39  Acquisition and use of environmentally preferable products and services.

    As prescribed in 48 CFR (DEAR) 970.2304-2, insert the following 
clause in management and operating contracts.

Acquisition and Use of Environmentally Preferable Products and Services 
                               (OCT 1995)

    (a) In the performance of this contract, the Contractor shall comply 
with the requirements of the following issuances:
    (1) Executive Order 12873 of October 20, 1993, entitled ``Federal 
Acquisition, Recycling, and Waste Prevention,''
    (2) Section 6002 of the Resource Conservation and Recovery Act 
(RCRA) of 1976, as amended (42 U.S.C. 6962, Pub. L. 94-580, 90 Stat. 
2822),
    (3) Title 40 of the Code of Federal Regulations, subchapter I, part 
247 (Comprehensive Guidelines for the Procurement of Products Containing 
Recovered Materials) and such other subchapter I parts or Comprehensive 
Procurement Guidelines as the Environmental Protection Agency may issue 
from time to time as guidelines for the procurement of products that 
contain recovered/recycled materials,
    (4) ``U.S. Department of Energy Affirmative Procurement Program for 
Products Containing Recovered Materials'' and related guidance 
document(s), as they are identified in writing by the Department.
    (b) The Contractor shall prepare and submit reports on matters 
related to the use of environmentally preferable products and services 
from time to time in accordance with written direction (e.g., in a 
specified format) from the Contracting Officer.
    (c) In complying with the requirements of paragraph (a) of this 
clause, the Contractor shall coordinate its concerns and seek 
implementing guidance on Federal and Departmental policy, plans, and 
program guidance with the DOE recycling point of contact, who shall be 
identified by the Contracting Officer. Reports required pursuant to 
paragraph (b) of this clause, shall be submitted through the DOE 
recycling point of contact.
[60 FR 47492, Sept. 13, 1995]



970.5204-40  Technology transfer mission.

    As prescribed in 48 CFR 970.73, insert the following clause:

                 Technology Transfer Mission (Jan. 1996)

    This clause has as its purpose implementation of the National 
Competitiveness Technology Transfer Act of 1989 (Sections 3131, 3132, 
3133, and 3157 of Pub. L. 101-189 and as amended by Pub. L. 103-160, 
Sections 3134 and 3160). The Contractor shall conduct technology 
transfer activities with a purpose of providing benefit from Federal 
research to U.S. industrial competitiveness.
    (a) Authority. (1) In order to ensure the full use of the results of 
research and development efforts of, and the capabilities of, the 
Laboratory, technology transfer, including Cooperative Research and 
Development Agreements (CRADAs), is established as a mission of the 
Laboratory consistent with the policy, principles and purposes of 
Sections 11(a)(1) and 12(g) of the Stevenson-Wydler Technology 
Innovation Act of 1980,

[[Page 490]]

as amended (15 U.S.C. 3710a); Section 3132(b) of Pub. L. 101-189, 
Sections 3134 and 3160 of P.L. 103-160, and of Chapter 38 of the Patent 
Laws (35 U.S.C. 200 et seq.); Section 152 of the Atomic Energy Act of 
1954, as amended (42 U.S.C. 2182); Section 9 of the Federal Nonnuclear 
Energy Research and Development Act of 1974 (42 U.S.C. 5908); and 
Executive Order 12591 of April 10, 1987.
    (2) In pursuing the technology transfer mission, the Contractor is 
authorized to conduct activities including but not limited to: 
identifying and protecting Intellectual Property made, created or 
acquired at or by the Laboratory; negotiating licensing agreements and 
assignments for Intellectual Property made, created or acquired at or by 
the Laboratory that the Contractor controls or owns; bailments; 
negotiating all aspects of and entering into CRADAs; providing technical 
consulting and personnel exchanges; conducting science education 
activities and reimbursable Work for Others (WFO); providing information 
exchanges; and making available laboratory or weapon production user 
facilities. It is fully expected that the Contractor shall use all of 
the mechanisms available to it to accomplish this technology transfer 
mission, including, but not limited to, CRADAs, user facilities, WFO, 
science education activities, consulting, personnel, assignments, and 
licensing in accordance with this clause.
    (b) Definitions.
    (1) Contractor's Laboratory Director means the individual who has 
supervision over all or substantially all of the Contractor's operations 
at the Laboratory.
    (2) Intellectual Property means patents, trademarks, copyrights, 
mask works, protected CRADA information, and other forms of comparable 
property rights protected by Federal Law and other foreign counterparts.
    (3) Cooperative Research and Development Agreement (CRADA) means any 
agreement entered into between the Contractor as operator of the 
Laboratory, and one or more parties including at least one non-Federal 
party under which the Government, through its laboratory, provides 
personnel, services, facilities, equipment, intellectual property, or 
other resources with or without reimbursement (but not funds to non-
Federal parties) and the non-Federal parties provide funds, personnel, 
services, facilities, equipment, intellectual property, or other 
resources toward the conduct of specified research or development 
efforts which are consistent with the missions of the Laboratory; except 
that such term does not include a procurement contract, grant, or 
cooperative agreement as those terms are used in sections 6303, 6304, 
and 6305 of Title 31 of the United States Code.
    (4) Joint Work Statement (JWS) means a proposal for a CRADA prepared 
by the Contractor, signed by the Contractor's Laboratory Director or 
designee which describes the following:
    (i) Purpose;
    (ii) Scope of Work which delineates the rights and responsibilities 
of the Government, the Contractor and Third Parties, one of which must 
be a non-Federal party;
    (iii) Schedule for the work; and
    (iv) Cost and resource contributions of the parties associated with 
the work and the schedule.
    (5) Assignment means any agreement by which the Contractor transfers 
ownership of Laboratory Intellectual Property, subject to the 
Government's retained rights.
    (6) Laboratory Biological Materials means biological materials 
capable of replication or reproduction, such as plasmids, 
deoxyribonucleic acid molecules, ribonucleic acid molecules, living 
organisms of any sort and their progeny, including viruses, prokaryote 
and eukaryote cell lines, transgenic plants and animals, and any 
derivatives or modifications thereof or products produced through their 
use or associated biological products, made under this contract by 
Laboratory employees or through the use of Laboratory research 
facilities.
    (7) Laboratory Tangible Research Product means tangible material 
results of research which
    (i) are provided to permit replication, reproduction, evaluation or 
confirmation of the research effort, or to evaluate its potential 
commercial utility;
    (ii) are not materials generally commercially available; and
    (iii) were made under this contract by Laboratory employees or 
through the use of Laboratory research facilities.
    (8) Bailment means any agreement in which the Contractor permits the 
commercial or non- commercial transfer of custody, access or use of 
Laboratory Biological Materials or Laboratory Tangible Research Product 
for a specified purpose of technology transfer or research and 
development, including without limitation evaluation, and without 
transferring ownership to the bailee.
    (c) Allowable Costs. (1) The Contractor shall establish and carry 
out its technology transfer efforts through appropriate organizational 
elements consistent with the requirements for an Office of Research and 
Technology Applications (ORTA) pursuant to paragraphs (b) and (c) of 
Section 11 of the Stevenson-Wydler Technology Innovation Act of 1980, as 
amended (15 U.S.C. 3710). The costs associated with the conduct of 
technology transfer through the ORTA including activities associated 
with obtaining, maintaining, licensing, and assigning Intellectual 
Property rights, increasing the potential for the transfer of 
technology, and the widespread notice of technology transfer 
opportunities, shall be deemed allowable provided

[[Page 491]]

that such costs meet the other requirements of the allowable costs 
provisions of this Contract. In addition to any separately designated 
funds, these costs in any fiscal year shall not exceed an amount equal 
to 0.5 percent of the operating funds included in the Federal research 
and development budget (including Work For Others) of the Laboratory for 
that fiscal year without written approval of the Contracting Officer.
    (2) The Contractor's participation in litigation to enforce or 
defend Intellectual Property claims incurred in its technology transfer 
efforts shall be as provided in the clause entitled ``Litigation and 
Claims'' of this Contract.
    (d) Conflicts of Interest--Technology Transfer. The Contractor shall 
have implementing procedures that seek to avoid employee and 
organizational conflicts of interest, or the appearance of conflicts of 
interest, in the conduct of its technology transfer activities. These 
procedures shall apply to other persons participating in Laboratory 
research or related technology transfer activities. Such implementing 
procedures shall be provided to the Contracting Officer for review and 
approval within sixty (60) days after execution of this contract. The 
Contracting Officer shall have thirty (30) days thereafter to approve or 
require specific changes to such procedures. Such implementing 
procedures shall include procedures to:
    (1) Inform employees of and require conformance with standards of 
conduct and integrity in connection with the CRADA activity in 
accordance with the provisions of paragraph (n)(5) of this clause;
    (2) Review and approve employee activities so as to avoid conflicts 
of interest arising from commercial utilization activities relating to 
Contractor-developed Intellectual Property;
    (3) Conduct work performed using royalties so as to avoid 
interference with or adverse effects on ongoing DOE projects and 
programs;
    (4) Conduct activities relating to commercial utilization of 
Contractor-developed Intellectual Property so as to avoid interference 
with or adverse effects on user facility or WFO activities of the 
Contractor;
    (5) Conduct DOE-funded projects and programs so as to avoid the 
appearance of conflicts of interest or actual conflicts of interest with 
non-Government funded work;
    (6) Notify the Contracting Officer with respect to any new work to 
be performed or proposed to be performed under the Contract for DOE or 
other Federal agencies where the new work or proposal involves 
Intellectual Property in which the Contractor has obtained or intends to 
request or elect title;
    (7) Except as provided elsewhere in this Contract, obtain the 
approval of the Contracting Officer for any licensing of or assignment 
of title to Intellectual Property rights by the Contractor to any 
business or corporate affiliate of the Contractor;
    (8) Obtain the approval of the Contracting Officer prior to any 
assignment, exclusive licensing, or option for exclusive licensing, of 
Intellectual Property to any person who has been a Laboratory employee 
within the previous two years or to the company in which he or she is a 
principal; and
    (9) Notify non-Federal sponsors of WFO activities, or non-Federal 
users of user facilities, of any relevant Intellectual Property interest 
of the Contractor prior to execution of WFOs or user agreements.
    (10) Notify DOE prior to evaluating a proposal by a third party or 
DOE, when the subject matter of the proposal involves an elected or 
waived subject invention under this contract or one in which the 
Contractor intends to elect to retain title under this contract.
    (e) Fairness of Opportunity. In conducting its technology transfer 
activities, the Contractor shall prepare procedures and take all 
reasonable measures to ensure widespread notice of availability of 
technologies suited for transfer and opportunities for exclusive 
licensing and joint research arrangements. The requirement to widely 
disseminate the availability of technology transfer opportunities does 
not apply to a specific application originated outside of the Laboratory 
and by entities other than the Contractor.
    (f) U.S. Industrial Competitiveness. (1) In the interest of 
enhancing U.S. Industrial Competitiveness, the Contractor shall, in its 
licensing and assignments of Intellectual Property, give preference in 
such a manner as to enhance the accrual of economic and technological 
benefits to the U.S. domestic economy. The Contractor shall consider the 
following factors in all of its licensing and assignment decisions 
involving Laboratory intellectual property where the Laboratory obtains 
rights during the course of the Contractor's operation of the Laboratory 
under this contract:
    (i) whether any resulting design and development will be performed 
in the United States and whether resulting products, embodying parts, 
including components thereof, will be substantially manufactured in the 
United States; or
    (ii) (A) whether the proposed licensee or assignee has a business 
unit located in the United States and whether significant economic and 
technical benefits will flow to the United States as a result of the 
license or assignment agreement; and
    (B) in licensing any entity subject to the control of a foreign 
company or government, whether such foreign government permits United 
States agencies, organizations or

[[Page 492]]

other persons to enter into cooperative research and development 
agreements and licensing agreements, and has policies to protect United 
States Intellectual Property rights.
    (2) If the Contractor determines that neither of the conditions in 
paragraphs (f)(1)(i) or (ii) of this clause are likely to be fulfilled, 
the Contractor, prior to entering into such an agreement, must obtain 
the approval of the Contracting Officer. The Contracting Officer shall 
act on any such requests for approval within thirty (30) days.
    (3) The Contractor agrees to be bound by the provisions of 35 U.S.C. 
204 (Preference for United States industry).
    (g) Indemnity--Product Liability. In entering into written 
technology transfer agreements, including but not limited to, research 
and development agreements, licenses, assignments and CRADAs, the 
Contractor agrees to include in such agreements a requirement that the 
U.S. Government and the Contractor, except for any negligent acts or 
omissions of the Contractor, be indemnified for all damages, costs, and 
expenses, including attorneys' fees, arising from personal injury or 
property damage occurring as a result of the making, using or selling of 
a product, process or service by or on behalf of the Participant, its 
assignees or licensees which was derived from the work performed under 
the agreement. The Contractor shall identify and obtain the approval of 
the Contracting Officer for any proposed exceptions to this requirement 
such as where State or local law expressly prohibit the Participant from 
providing indemnification or where the research results will be placed 
in the public domain.
    (h) Disposition of Income. (1) Royalties or other income earned or 
retained by the Contractor as a result of performance of authorized 
technology transfer activities herein shall be used by the Contractor 
for scientific research, development, technology transfer, and education 
at the Laboratory, consistent with the research and development mission 
and objectives of the Laboratory and subject to Section 12(b)(5) of the 
Stevenson-Wydler Technology Innovation Act of 1980, as amended (15 
U.S.C. 3710a(b)(5)) and Chapter 38 of the Patent Laws (35 U.S.C. 200 et 
seq.) as amended through the effective date of this contract award or 
modification. If the net amounts of such royalties and income received 
from patent licensing after payment of patenting costs, licensing costs, 
payments to inventors and other expenses incidental to the 
administration of Subject Inventions during any fiscal year exceed 5 
percent of the Laboratory's budget for that fiscal year, 75 percent of 
such excess amounts shall be paid to the Treasury of the United States, 
and the remaining amount of such excess shall be used by the Contractor 
for the purposes as described above in this paragraph. Any inventions 
arising out of such scientific research and development activities shall 
be deemed to be Subject Inventions under the Contract.
    (2) The Contractor shall include as a part of its annual Laboratory 
Institutional Plan or other such annual document a plan setting out 
those uses to which royalties and other income received as a result of 
performance of authorized technology transfer activities herein will be 
applied at the Laboratory, and at the end of the year, provide a 
separate accounting for how the funds were actually used. Under no 
circumstances shall these royalties and income be used for an illegal 
augmentation of funds furnished by the U.S. Government.
    (3) The Contractor shall establish subject to the approval of the 
Contracting Officer a policy for making awards or sharing of royalties 
with Contractor employees, other coinventors and coauthors, including 
Federal employee coinventors when deemed appropriate by the Contracting 
Officer.
    (i) Transfer to Successor Contractor. In the event of termination or 
upon the expiration of this Contract, any unexpended balance of income 
received for use at the Laboratory shall be transferred, at the 
Contracting Officer's request, to a successor contractor, or in the 
absence of a successor contractor, to such other entity as designated by 
the Contracting Officer. The Contractor shall transfer title, as one 
package, to the extent the Contractor retains title, in all patents and 
patent applications, licenses, accounts containing royalty revenues from 
such license agreements, including equity positions in third party 
entities, and other Intellectual Property rights which arose at the 
Laboratory, to the successor contractor or to the Government as directed 
by the Contracting Officer.
    (j) Technology Transfer Affecting the National Security. (1) The 
Contractor shall notify and obtain the approval of the Contracting 
Officer, prior to entering into any technology transfer arrangement, 
when such technology or any part of such technology is classified or 
sensitive under Section 148 of the Atomic Energy Act (42 U.S.C. 2168). 
Such notification shall include sufficient information to enable DOE to 
determine the extent that commercialization of such technology would 
enhance or diminish security interests of the United States, or diminish 
communications within DOE's nuclear weapon production complex. DOE shall 
use its best efforts to complete its determination within sixty (60) 
days of the Contractor's notification, and provision of any supporting 
information, and DOE shall promptly notify the Contractor as to whether 
the technology is transferable.
    (2) The Contractor shall include in all of its technology transfer 
agreements with third parties, including, but not limited to,

[[Page 493]]

CRADAs, licensing agreements and assignments, notice to such third 
parties that the export of goods and/or Technical Data from the United 
States may require some form of export control license or other 
authority from the U.S. Government and that failure to obtain such 
export control license may result in criminal liability under U.S. laws.
    (3) For other than fundamental research as defined in National 
Security Decision Directive 189, the Contractor is responsible to 
conduct internal export control reviews and assure that technology is 
transferred in accordance with applicable law.
    (k) Records. The Contractor shall maintain records of its technology 
transfer activities in a manner and to the extent satisfactory to the 
DOE and specifically including, but not limited to, the licensing 
agreements, assignments and the records required to implement the 
requirements of paragraphs (e), (f), and (h) of this clause and shall 
provide reports to the Contracting Officer to enable DOE to maintain the 
reporting requirements of Section 12(c)(6) of the Stevenson-Wydler 
Technology Innovation Act of 1980, as amended (15 U.S.C. 3710a(c)(6)). 
Such reports shall be made annually in a format to be agreed upon 
between the Contractor and DOE and in such a format which will serve to 
adequately inform DOE of the Contractor's technology transfer activities 
while protecting any data not subject to disclosure under the Rights in 
Technical Data clause and paragraph (n) of this clause. Such records 
shall be made available in accordance with the clauses of this Contract 
pertaining to inspection, audit and examination of records.
    (l) Reports to Congress. To facilitate DOE's reporting to Congress, 
the Contractor is required to submit annually to DOE a technology 
transfer plan for conducting its technology transfer function for the 
upcoming year, including plans for securing Intellectual Property rights 
in Laboratory innovations with commercial promise and plans for managing 
such innovations so as to benefit the competitiveness of United States 
industry. This plan shall be provided to the Contracting Officer on or 
before October 1st of each year.
    (m) Oversight and Appraisal. The Contractor is responsible for 
developing and implementing effective internal controls for all 
technology transfer activities consistent with the audit and record 
requirements of this Contract. Laboratory Contractor performance in 
implementing the technology transfer mission and the effectiveness of 
the Contractor's procedures will be evaluated by the Contracting Officer 
as part of the annual appraisal process, with input from the cognizant 
Secretarial Officer or program office.
    (n) Technology Transfer Through Cooperative Research and Development 
Agreements. Upon approval of the Contracting Officer and as provided in 
a DOE approved Joint Work Statement (JWS), the Laboratory Director or 
his designee may enter into CRADAs on behalf of the DOE subject to the 
requirements set forth in this paragraph.
    (1) Review and Approval of CRADAs (i) Except as otherwise directed 
in writing by the Contracting Officer, each JWS shall be submitted to 
the Contracting Officer for approval. The Contractor's Laboratory 
Director or designee shall provide a program mission impact statement 
and shall include an impact statement regarding related Intellectual 
Property rights known by the Contractor to be owned by the Government to 
assist the Contracting Officer in his approval determination.
    (ii) The Contractor shall also include (specific to the proposed 
CRADA), a statement of compliance with the Fairness of Opportunity 
requirements of paragraph (e) of this clause.
    (iii) Within ninety (90) days after submission of a JWS, the 
Contracting Officer shall approve, disapprove or request modification to 
the JWS. If a modification is required, the Contracting Officer shall 
approve or disapprove any resubmission of the JWS within thirty (30) 
days of its resubmission, or ninety (90) days from the date of the 
original submission, whichever is later. The Contracting Officer shall 
provide a written explanation to the Contractor's Laboratory Director or 
designee of any disapproval or requirement for modification of a JWS.
    (iv) Upon approval of a JWS, the Contractor's Laboratory Director or 
designee may submit a CRADA, based upon the approved JWS, to the 
Contracting Officer. The Contracting Officer, within thirty (30) days of 
receipt of the CRADA, shall approve or request modification of the 
CRADA. If the Contracting Officer requests a modification of the CRADA, 
an explanation of such request shall be provided to the Laboratory 
Director or designee.
    (v) Except as otherwise directed in writing by the Contracting 
Officer, the Contractor shall not enter into, or begin work under, a 
CRADA until approval of the CRADA has been granted by the Contracting 
Officer. The Contractor may submit its proposed CRADA to the Contracting 
Officer at the time of submitting its proposed JWS or any time 
thereafter. However, the Contracting Officer is not obligated to respond 
under paragraph (n)(1)(iv) of this clause until within thirty (30) days 
after approval of the JWS or thirty (30) days after submittal of the 
CRADA, whichever is later.
    (2) Selection of Participants The Contractor's Laboratory Director 
or designee in deciding what CRADA to enter into shall:
    (i) Give special consideration to small business firms, and 
consortia involving small business firms;
    (ii) Give preference to business units located in the United States 
which agree that products or processes embodying Intellectual

[[Page 494]]

Property will be substantially manufactured or practiced in the United 
States and, in the case of any industrial organization or other person 
subject to the control of a foreign company or government, take into 
consideration whether or not such foreign government permits United 
States agencies, organizations, or other persons to enter into 
cooperative research and development agreements and licensing 
agreements;
    (iii) Provide Fairness of Opportunity in accordance with the 
requirements of paragraph (e) of this clause; and
    (iv) Give consideration to the Conflicts of Interest requirements of 
paragraph (d) of this clause.
    (3) Withholding of Data (i) Data that is first produced as a result 
of research and development activities conducted under a CRADA and that 
would be a trade secret or commercial or financial data that would be 
privileged or confidential, if such data had been obtained from a non-
Federal third party, may be protected from disclosure under the Freedom 
of Information Act as provided in the Stevenson- Wydler Technology 
Innovation Act of 1980, as amended (15 U.S.C. 3710a(c)(7)) for a period 
as agreed in the CRADA of up to five (5) years from the time the data is 
first produced. The DOE shall cooperate with the Contractor in 
protecting such data.
    (ii) Unless otherwise expressly approved by the Contracting Officer 
in advance for a specific CRADA, the Contractor agrees, at the request 
of the Contracting Officer, to transmit such data to other DOE 
facilities for use by DOE or its Contractors by or on behalf of the 
Government. When data protected pursuant to paragraph (n)(3)(i) of this 
clause is so transferred, the Contractor shall clearly mark the data 
with a legend setting out the restrictions against private use and 
further dissemination, along with the expiration date of such 
restrictions.
    (iii) In addition to its authority to license Intellectual Property, 
the Contractor may enter into licensing agreements with third parties 
for data developed by the Contractor under a CRADA subject to other 
provisions of this Contract. However, the Contractor shall neither use 
the protection against dissemination nor the licensing of data as an 
alternative to the submittal of invention disclosures which include data 
protected pursuant to paragraph (n)(3)(i) of this clause.
    (4) Work For Others and User Facility Programs (i) WFO and User 
Facility Agreements (UFAs) are not CRADAs and will be available for use 
by the Contractor in addition to CRADAs for achieving utilization of 
employee expertise and unique facilities for maximizing technology 
transfer. The Contractor agrees to inform prospective CRADA 
participants, which are intending to substantially pay full cost 
recovery for the effort under a proposed CRADA, of the availability of 
alternative forms of agreements, i.e., WFO and UFA, and of the Class 
Patent Waiver provisions associated therewith.
    (ii) Where the Contractor believes that the transfer of technology 
to the U. S. domestic economy will benefit from, or other equity 
considerations dictate, an arrangement other than the Class Waiver of 
patent rights to the sponsor in WFO and UFAs, a request may be made to 
the Contracting Officer for an exception to the Class Waivers.
    (iii) Rights to inventions made under agreements other than funding 
agreements with third parties shall be governed by the appropriate 
provisions incorporated, with DOE approval, in such agreements, and the 
provisions in such agreements take precedence over any disposition of 
rights contained in this Contract. Disposition of rights under any such 
agreement shall be in accordance with any DOE class waiver (including 
Work for Others and User Class Waivers) or individually negotiated 
waiver which applies to the agreement.
    (5) Conflicts of Interest (i) Except as provided in paragraph 
(n)(5)(iii) of this clause, the Contractor shall assure that no employee 
of the Contractor shall have a substantial role (including an advisory 
role) in the preparation, negotiation, or approval of a CRADA, if, to 
such employee's knowledge:
    (A) Such employee, or the spouse, child, parent, sibling, or partner 
of such employee, or an organization (other than the Contractor) in 
which such employee serves as an officer, director, trustee, partner, or 
employee--
    (1) holds financial interest in any entity, other than the 
Contractor, that has a substantial interest in the preparation, 
negotiation, or approval of the CRADA;
    (2) receives a gift or gratuity from any entity, other than the 
Contractor, that has a substantial interest in the preparation, 
negotiation, or approval of the CRADA; or
    (B) A financial interest in any entity, other than the Contractor, 
that has a substantial interest in the preparation, negotiation, or 
approval of the CRADA, is held by any person or organization with whom 
such employee is negotiating or has any arrangement concerning 
prospective employment.
    (ii) The Contractor shall require that each employee of the 
Contractor who has a substantial role (including an advisory role) in 
the preparation, negotiation, or approval of a CRADA certify through the 
Contractor to the Contracting Officer that the circumstances described 
in paragraph (n)(5)(i) of this clause do not apply to that employee.
    (iii) The requirements of paragraphs (n)(5)(i) and (n)(5)(ii) of 
this clause shall not apply in a case where the Contracting Officer is 
advised by the Contractor in advance of the participation of an employee 
described in those paragraphs in the preparation, negotiation or 
approval of a CRADA of the nature

[[Page 495]]

of and extent of any financial interest described in paragraph (n)(5)(i) 
of this clause, and the Contracting Officer determines that such 
financial interest is not so substantial as to be considered likely to 
affect the integrity of the Contractor employee's participation in the 
process of preparing, negotiating, or approving the CRADA.
    (o) Technology Transfer in Other Cost-Sharing Agreements. In 
conducting research and development activities in cost-shared agreements 
not covered by paragraph (n) of this clause, the Contractor, with prior 
written permission of the Contracting Officer, may provide for the 
withholding of data produced thereunder in accordance with the 
applicable provisions of paragraph (n)(3) of this clause.

                             (End of clause)

    Alternate I (Jan 1996). As prescribed in 970.7330(b), add the 
following definition under paragraph (b) and new paragraph (p):

    (b)(8) Privately funded technology transfer means the prosecuting, 
maintaining, licensing, and marketing of inventions which are not owned 
by the Government (and not related to CRADAs) when such activities are 
conducted entirely without the use of Government funds.
    (p) Nothing in paragraphs (c) Allowable Costs, (e) Fairness of 
Opportunity, (f) U.S. Industrial Competitiveness, (g) Indemnity - 
Product Liability, (h) Disposition of Income, and (i) Transfer to 
Successor Contractor of this clause are intended to apply to the 
contractor's privately funded technology transfer activities if such 
privately funded activities are addressed elsewhere in the contract.

    Alternate II (Jan 1996). As prescribed in 970.7330(c), the phrase 
``weapon production facility'' may be substituted wherever the word 
``laboratory'' appears in the clause.
[60 FR 66512, Dec. 22, 1995]



970.5204-41  [Reserved]



970.5204-42  Key personnel.

    As prescribed in 970.2201(b)(1), insert the following clause.

                        Key Personnel (Apr 1984)

    It having been determined that the employees whose names appear 
(below or in Appendix ____), or persons approved by the contracting 
officer as persons of substantially equal abilities and qualifications, 
are necessary for the successful performance of this contract, the 
contractor agrees to assign such employees or persons to the performance 
of the work under this contract and shall not reassign or remove any of 
them without the consent of the contracting officer. Whenever, for any 
reason, one or more of the aforementioned employees is unavailable for 
assignment for work under the contract, the contractor shall, with the 
approval of the contracting officer, replace such employee with an 
employee of substantially equal abilities and qualifications.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9111, Feb. 25, 1994]



970.5204-43  Other Government contractors.

    Insert the following clause, when appropriate.

                 Other Government Contractors (Apr 1994)

    The Government may undertake or award other contracts for additional 
work or services. The contractor agrees to fully cooperate with such 
other contractors and Government employees and carefully fit its own 
work to such other work as may be directed by the contracting officer. 
The contractor shall not commit or permit any act which will interfere 
with the performance of work by any other contractor or by Government 
employees.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9112, Feb. 25, 1994; 62 
FR 2313, Jan. 16, 1997]



970.5204-44  Flowdown of contract requirements to subcontracts.

    Insert the following clause.

      Flowdown of Contract Requirements to Subcontracts (FEB 1997)

    (a) The contractor shall include the clauses in paragraph (b) of 
this clause in appropriate subcontracts.
    (1) To the extent that the clause is included in this prime 
contract, the contractor shall comply with that portion of the clause 
that directs application to subcontracts.
    (2) To the extent that the clause is not included in this prime 
contract, or where it is included but there is no instruction for 
treatment in subcontracts, the contractor shall include the clause in 
accordance with applicable regulatory guidance which would apply if the 
subcontract were a prime contract with the Federal government.
    (3) In all cases, where a regulation is cited, the contractor shall 
comply with the regulation in administration of the related clause.
    (b) Clauses and related regulations.
    (1) Air Transportation by U.S.-Flag Carriers. Clause at FAR 52.247-
63.
    (2) Anti-Kickback Act of 1986. Clause at FAR 52.203-7.
    (3) Clean Air and Water. Clause at FAR 52.223-2, and follow the 
requirements of FAR 23.1.

[[Page 496]]

    (4) Contract Work Hours and Safety Standards Act. Clause at FAR 
52.222-4, and follow the requirements of FAR 22.3.
    (5) Cost or Pricing Data. Clause at 48 CFR (DEAR) 970.5204-24.
    (6) Cost and Schedule Control Systems. Clause at 48 CFR (DEAR) 
970.5204-50.
    (7) Cost Accounting Standards. Clause at FAR 52.230-2, as prescribed 
in 48 CFR (DEAR) 970.30.
    (8) Davis-Bacon Act. Clauses as directed at FAR 22.407, and follow 
the requirements of FAR 22.4 to the same extent that they would apply if 
the subcontract had been directly awarded by DOE. 48 CFR (DEAR) Subpart 
922.4 and 48 CFR (DEAR) 970.2273 provide guidance to assist in 
determining the applicability of these regulations.
    (9) Employment of the Handicapped. Clause at FAR 52.222-36, and 
follow the requirements of FAR 22.14.
    (10) Environmental and Occupational Safety and Health. Clauses as 
prescribed in 48 CFR (DEAR) 970.2303-2.
    (11) Equal Employment Opportunity. Clauses as prescribed in FAR 
22.810, as applicable, and follow the requirements of FAR 22.8, 48 CFR 
(DEAR) 922.8, E.O. 11246 and 41 CFR part 60.
    (12) [Reserved]
    (13) Foreign Travel. Clause at 48 CFR (DEAR) 970.5204-52.
    (14) Nuclear Hazards Indemnity. Clause at 48 CFR (DEAR) 970.2870.
    (15) Organizational Conflicts of Interest. Clause at 48 CFR (DEAR) 
952.209-72 in accordance with 48 CFR (DEAR) 970.0905.
    (16) Patent, Data and Copyrights. Appropriate clauses as required by 
48 CFR (DEAR) parts 927 and 970.
    (17) Printing. Clause at 48 CFR (DEAR) 970.5204-19.
    (18) Privacy Act. Clauses at FAR 52.224-1 and FAR 52.224-2, and 
follow the requirements of FAR 24.1.
    (19) Accounts, Records, and Inspection. Clause at 48 CFR (DEAR) 
970.5204-9.
    (20) Safeguarding Classified Information. Appropriate clauses as 
prescribed at 48 CFR (DEAR) 970.0404.
    (21) Service Contract Act. Clauses at FAR 52.222-40 and FAR 52.222-
41.
    (22) Small Business and Small Disadvantaged Business Concerns. 
Clause at FAR 52.219-9.
    (23) Special Disabled and Vietnam Era Veterans. Clause at FAR 
52.222-35, and follow the requirements of FAR Subpart 22.13.
    (24) Taxes. Clause similar to 48 CFR (DEAR) 970.5204-23 cost-
reimbursement. An appropriate tax clause covering tax matters should 
also be included in fixed-price subcontracts.
    (25) Termination. Appropriate clause or clauses as set forth at FAR 
52.249-1 through 52.249-14.
    (c) Other. Omission from the foregoing list of contract flowdown 
provisions shall not be construed as waiving a requirement for the 
contractor to comply with a flowdown requirement for subcontracts 
appearing elsewhere in this contract.
[60 FR 49517, Sept. 26, 1995, as amended at 61 FR 21978, May 13, 1996; 
61 FR 30823, June 18, 1996; 62 FR 2313, Jan. 16, 1997; 62 FR 40753, July 
30, 1997]



970.5204-45  Termination.

    As prescribed in 970.7104-30, insert the following clause.

                         Termination (OCT 1995)

    (a) This contract shall continue until ______ unless sooner 
terminated in accordance with the provisions which follow:
    (1) The performance of work under this contract may be terminated by 
the Government in whole, or from time to time in part, (i) whenever the 
contractor shall default in performance, and shall fail to cure the 
fault or failure within such period as the contracting officer may allow 
after receipt from the contracting officer of a notice specifying the 
fault or failure, or (ii) whenever, for any reason, the contracting 
officer shall determine any such termination is for the best interest of 
the Government. Termination of the work hereunder shall be effected by 
delivery of a notice of termination specifying whether termination is 
for default of the contractor or for the convenience of the Government, 
the extent to which performance of work under the contract shall be 
terminated, and the date upon which such termination shall become 
effective. Any such termination shall be without prejudice to any claim 
which either party may have against the other. If, after notice of 
termination under the provisions of paragraph (a)(1)(i) of this section, 
it is determined for any reason that the contractor was not in default, 
such notice of default shall be deemed to have been issued pursuant to 
paragraph (a)(1)(ii) of this section, and the rights and obligations of 
the parties hereto shall in such event be governed accordingly.
    (2) Upon receipt of notice of termination, in accordance with (1) 
above, the contractor shall, to the extent directed in writing by the 
contracting officer, discontinue the terminated work and the placing of 
orders for materials, facilities, supplies, and services in connection 
therewith, and shall proceed, if, and to the extent required by the 
contracting officer, to cancel promptly and settle with the approval of 
the contracting officer, existing orders, subcontracts, and commitments 
insofar as such orders, subcontracts, and commitments pertain to this 
contract.
    (b) Upon the termination of this contract, full and complete 
settlement of all claims of the contractor and of DOE arising out of 
this contract shall be made as follows:

[[Page 497]]

    (1) The Government shall have the right in its discretion to assume 
sole responsibility for any or all obligations, commitments, and claims 
that the contractor may have undertaken or incurred, the cost of which 
are allowable in accordance with the provisions of this contract; and 
the contractor shall, as a condition of receiving the payments mentioned 
in this article, execute and deliver all such papers and; take all such 
steps as the contracting officer may require for the purpose of fully 
vesting in the Government any rights and benefits the contractor may 
have under or in connection with such obligations, commitments, or 
claims.
    (2) The Government shall treat as allowable costs all expenditures 
made in accordance with and allowable under the clause entitled 
``Allowable Costs and Fixed Fee,'' not previously so allowed or 
otherwise credited for work performed prior to the effective date of 
termination, together with expenditures as may be incurred for a 
reasonable time thereafter with the approval of, or as directed by, the 
contracting officer.
    (3) The Government shall treat as allowable costs, to the extent not 
included in paragraph (b)(2) of this section, the costs of settling and 
paying claims arising out of the termination of work under orders, 
subcontracts, and commitments as provided in paragraph (a)(2) of this 
section.
    (4) The Government shall treat as allowable costs the reasonable 
costs of settlement, including accounting, legal, clerical, and other 
expenses reasonably necessary for the preparation of settlement claims 
and supporting data with respect to the termination of the contract and 
for the termination and settlement of orders and subcontracts 
thereunder, together with such further expenditures made by the 
contractor after the date of termination for the protection or 
disposition of Government property as are approved or required by the 
contracting officer; provided, however, that if the termination is for 
default of the contractor, there shall not be included any amount for 
preparation of the contractor's settlement proposal.
    (5) If performance of work under this contract is terminated in 
whole by the Government, the fixed fee of the contractor shall be 
prorated to and including the effective date of such termination. In 
addition, if the termination is for the convenience of the Government, 
the contractor shall be paid a fixed fee in an amount to be agreed upon 
as compensation for its services in closing out the work under this 
contract after the effective date of such termination. The additional 
fixed fee is to be negotiated as soon as practicable after service of 
notice of termination, shall take into account the estimate of the cost 
of the services and managerial effort to be rendered under this clause 
after the effective date of termination, and shall be provided for in a 
supplement or amendment to this contract prior to final settlement 
hereunder. Pending agreement as to the amount of such fee, the 
contractor shall diligently proceed with the performance of the services 
required under this clause. No additional fee will be paid if the 
contract is terminated due to the default of the contractor. In the 
event of a partial termination by the Government, an equitable 
adjustment shall be made in the fixed fee if such termination results in 
a material decrease in the level of the contractor's management effort. 
Any failure to agree on the right to or the amount of any adjustment 
shall be deemed a dispute within the purview of the clause hereof 
entitled ``Disputes.''
    (6) The obligation of the Government to make any of the payments 
required by this clause or any other provisions of this contract shall 
be subject to any unsettled claims in connection with this contract 
which the Government may have against the contractor.
    (c) Prior to final settlement, the contractor shall furnish a 
release as required in the clause entitled ``Payments and Advances'' and 
account for Government-owned property as may be required by the 
contracting officer: provided, however, that unless the contracting 
officer requires an inventory, the maintenance and disposition of the 
records of Government-owned property in accordance with the clause 
entitled ``Accounts, Records and Inspection'' shall be accepted by the 
contracting officer as full compliance with all requirements of this 
contract pertaining to an accounting for such property.
[49 FR 12063, Mar. 28, 1984, as amended at 59 FR 9112, Feb. 25, 1994; 60 
FR 49518, Sept. 26, 1995; 62 FR 2313, Jan. 16, 1997]



970.5204-48  [Reserved]



970.5204-50  [Reserved]



970.5204-51  [Reserved]



970.5204-52  Foreign travel.

    When foreign travel may be required under the contract, insert the 
clause at 952.247-70.
[62 FR 2313, Jan. 16, 1997]



970.5204-53  Contractor employee travel discounts.

    Insert the contract clause at 952.251-70 when the circumstances 
described in 951.7002 apply.
[54 FR 17738, Apr. 25, 1989]

[[Page 498]]



970.5204-54  Basic fee and award fee.

    As prescribed in 970.1509-8(d), insert this clause in cost plus 
award fee management and operating contracts.

                   Basic Fee and Award Fee (APR 1994)

    (a) Basic Fee and Award Fee. It is herewith agreed that a basic fee 
and an award fee, to be determined in accordance with the provisions of 
this clause, are available for payment in accordance with the clause of 
this contract entitled Payments and Advances.
    (b) Fee Negotiations. Prior to the beginning of each fiscal year 
under this contract, or other appropriate period as mutually agreed 
upon, the contracting officer and contractor shall enter into 
negotiation of a basic and award fee. This contract shall be modified at 
the conclusion of each negotiation to reflect the negotiated amount for 
the basic fee and to identify the available award fee amount. It is 
herein agreed the award fee amount shall be assigned to evaluation 
periods six months in duration. If the parties are unable to agree on a 
reasonable fee, the contracting officer shall unilaterally determine the 
basic fee and the available award fee, subject to the clause of this 
contract entitled Disputes.
    (c) Determination of Award Fee Earned.
    (1) The Government shall, at the conclusion of each specified 
evaluation period, evaluate the contractor's performance for a 
determination of award fee earned.
    (2) For this contract, the Government Fee Determination Official 
(FDO) will be (insert title of FDO). The contractor agrees that the 
determination as to the amount of award fee earned will be made by the 
Government FDO and such determination is binding on both parties and 
shall not be subject to appeal under the ``Disputes'' clause or any 
other appeal clause.
    (3) The evaluation of contractor performance shall be in accordance 
with the Performance Evaluation Plan described in subparagraph (d), 
below. The contractor shall be promptly advised in writing of the 
determination, and the reasons why the award fee was or was not earned. 
While it is recognized that the basis for determination of the fee shall 
be the evaluation by the Government, in accordance with the Performance 
Evaluation Plan, the FDO may also consider any information available to 
him or her which relates to the contractor's performance of contract 
requirements. In the event that the contractor's performance is 
considered unacceptable in any area of contract performance which is 
specified in the Performance Evaluation Plan, even if no weight or fee 
is specifically assigned to the particular performance area, the FDO may 
at his/her discretion determine the contractor's overall performance to 
be unacceptable, and accordingly may withhold the entire award fee for 
the evaluation period.
    (4) An award fee cycle usually consists of two six-month award fee 
periods in a single fiscal year. Unearned award fee may be carried over 
within a single fiscal year, or other two-period fee negotiation cycle, 
as may have been agreed upon. The FDO may, at his/her sole discretion, 
specify in a fee determination that award fee not earned during the 
first evaluation period of a two-period fee cycle may be allocated to 
the second fee period in that fee cycle. The contractor shall not, 
however, be entitled to earn any of this ``carry-over'' fee if its 
overall performance in the latter evaluation period does not reflect an 
improvement over the prior evaluation period. Overall performance 
evaluations in the second period which are equal to or the same as those 
in the first period shall not be considered as improvements providing 
entitlement to the carry-over portion of the award fee pool. If the 
single negotiation of a basic and the resulting award fee amount (fee 
cycle) will be for more than two evaluation periods, unearned award fees 
in any one of the evaluation periods established by that negotiation may 
be carried over only to the next period covered by that negotiation. 
Fees unearned under one fee cycle may not be carried forward to another 
fee cycle.
    (d) Performance Evaluation Plan. (1) The Government shall establish 
unilaterally a Performance Evaluation Plan upon which the determination 
of the amount of award fee earned shall be based. Such Plan shall 
include the criteria to be considered under each area evaluated and the 
percentage of award fee available for each area. A copy of the Plan 
shall be provided to the contractor thirty (30) calendar days prior to 
the start of an evaluation period.
    (2) The Performance Evaluation Plan will set forth the criteria upon 
which the contractor will be evaluated for performance relating to any 
technical, schedule, management, and/or cost objectives selected for 
evaluation.
    (3) The Performance Evaluation Plan may, consistent with the 
contract statement of work, be revised unilaterally by the Government at 
any time during the period of performance. Notification of such changes 
shall be provided to the contractor at least thirty (30) calendar days 
prior to the start of the evaluation period to which the change will 
apply.
    (e) Contractor Self-Assessment. Following each evaluation period, 
the contractor shall submit a self-assessment within (Insert Number) 
calendar days after the end of the period. This self-assessment shall 
address both the strengths and weaknesses of the contractor's 
performance during the evaluation period. Where deficiencies in 
performance are noted, the contractor shall describe the actions planned 
or taken to correct such

[[Page 499]]

deficiencies and avoid their recurrence. The FDO will review the 
contractor's self-assessment as part of his/her evaluation of the 
contractor's management during the period. An unrealistic self-
assessment will result in lower award fee determinations. The contractor 
will not be penalized for a realistic self-assessment, although 
deficiencies noted by the contractor may be reflected in the 
Government's evaluation. The self-assessment itself will not be the 
basis for the award fee determination.
    (f) Schedule for Award Determinations. The FDO shall issue the final 
award fee determination in accordance with a schedule set forth in the 
Performance Evaluation Plan. However, a determination must be made 
within sixty (60) calendar days after the receipt by the contracting 
officer of the contractor's self-assessment discussed in paragraph (e), 
above. If the determination is delayed beyond that date, the contractor 
shall be entitled to interest on the determined award fee amount at the 
rate established by the Secretary of the Treasury under section 12 of 
the Contract Disputes Act of 1978 (41 U.S.C. 611) that is in effect on 
the payment date. This rate is referred to as the ``Renegotiation Board 
Interest Rate,'' and is published in the Federal Register semiannually 
on or about January 1 and July 1. The interest on any late award fee 
determination amount will accrue daily and be compounded in 30-day 
increments inclusive from the first day after the schedule determination 
date through the actual date the determination is issued. That is, 
interest accrued at the end of any 30-day period will be added to the 
determined amount of award fee and be subject to interest if not paid in 
the succeeding 30-day period.
[56 FR 28108, June 19, 1991, as amended at 59 FR 9112, Feb. 25, 1994; 62 
FR 2313, Jan. 16, 1997]



970.5204-55  [Reserved]



970.5204-56  [Reserved]



970.5204-57  Agreement regarding workplace substance abuse programs at DOE facilities.

    As prescribed in 970.2305-4(a), insert the following provision:

Agreement Regarding Workplace Substance Abuse Programs at DOE Sites (SEP 
                                  1997)

    (a) Any contract awarded as a result of this solicitation will be 
subject to the policies, criteria, and procedures of 10 CFR part 707, 
Workplace Substance Abuse Programs at DOE Sites.
    (b) By submission of its offer, the officer agrees to provide to the 
contracting officer, within 30 days after notification of selection for 
award, or award of a contract, whichever occurs first, pursuant to this 
solicitation, its written workplace substance abuse program consistent 
with the requirements of 10 CFR part 707.
    (c) Failure of the offeror to agree to the condition of 
responsibility set forth in paragraph (b) of this provision, renders the 
offeror unqualified and inelligible for award.

 _______________________________________________________________________
Signature of officer/employee certifying regarding the offeror's 
          workplace substance abuse program/Date
 _______________________________________________________________________
Typed name and title of signatory

(End of provision)
[57 FR 32677, July 22, 1992, as amended at 59 FR 9112, Feb. 25, 1994; 62 
FR 42075, Aug. 5, 1997]



970.5204-58  Workplace substance abuse programs at DOE sites.

    As prescribed in 970.2305-4(b), insert the following clause:

       Workplace Substance Abuse Programs at DOE Sites (Aug 1992)

    (a) Program Implementation. The contractor shall, consistent with 10 
CFR part 707, Workplace Substance Abuse Programs at DOE Sites, 
incorporated herein by reference with full force and effect, develop, 
implement, and maintain a workplace substance abuse program.
    (b) Remedies. In addition to any other remedies available to the 
Government, the contractor's failure to comply with the requirements of 
10 CFR part 707 or to perform in a manner consistent with its approved 
program may render the contractor subject to: the suspension of contract 
payments, or, where applicable, a reduction in award fee; termination 
for default; and suspension or debarment.
    (c) Subcontracts. (1) The contractor agrees to notify the 
contracting officer reasonably in advance of, but not later than 30 days 
prior to, the award of any subcontract the contractor believes may be 
subject to the requirements of 10 CFR part 707.
    (2) The DOE prime contractor shall require all subcontracts subject 
to the provisions of 10 CFR part 707 to agree to develop and implement a 
workplace substance abuse program that complies with the requirements of 
10 CFR part 707, Workplace Substance Abuse Programs at DOE Sites, as a 
condition for award of the subcontract. The DOE prime contractor shall 
review and approve each subcontractor's program, and shall periodically 
monitor each subcontractor's implementation of the program for 
effectiveness and compliance with 10 CFR part 707.

[[Page 500]]

    (3) The contractor agrees to include, and require the inclusion of, 
the requirements of this clause in all subcontracts, at any tier, that 
are subject to the provisions of 10 CFR part 707.

                             (End of clause)

[57 FR 32677, July 22, 1992, as amended at 59 FR 9112, Feb. 25, 1994]



970.5204-59  Whistleblower protection for contractor employees.

    As prescribed in 970.2274-2, insert the following clause in 
management and operating contracts. As prescribed and changed in 
922.7101, insert the following clause in certain contracts that are not 
management and operating contracts. As prescribed and changed in 
913.507, insert the following clause in certain purchase orders.

      Whistleblower Protection for Contractor Employees (Jan 1993)

    (a) The contractor shall comply with the requirements of the ``DOE 
Contractor Employee Protection Program'' at 10 CFR part 708.
    (b) The contractor shall insert or have inserted the substance of 
this clause, including this paragraph (b), in subcontracts, at all 
tiers, with respect to work performed on-site at a DOE- owned or leased 
facility, as provided for at 10 CFR part 708.
[57 FR 57640, Dec. 4, 1992; 58 FR 39679, July 26, 1993]



970.5204-60  Facilities management.

    Pursuant to 970.72 the following clause is to be used in contracts 
providing for contractor management of a DOE-owned or DOE-controlled 
facility or facilities.

    Facilities Management: (FEB 1997) Copies of DOE Directives 
referenced herein are available from the contracting officer.
    (a) Site development planning. The Government shall provide to the 
contractor site development guidance for the facilities and lands for 
which the contractor is responsible under the terms and conditions of 
this contract. Based upon this guidance, the contractor shall prepare, 
and maintain through annual updates, a Long-Range Site Development Plan 
(Plan) to reflect those actions necessary to keep the development of 
these facilities current with the needs of the Government and allow the 
contractor to successfully accomplish the work required under this 
contract. In developing this Plan, the contractor shall follow the 
procedural guidance set forth in DOE Directive 4320.1 (See current 
version.) version in effect on effective date of contract, entitled Site 
Development Planning. The contractor shall use the Plan to manage and 
control the development of facilities and lands. All plans and revisions 
shall be approved by the Government.
    (b) General design criteria. The general design criteria which shall 
be utilized by the contractor in managing the site for which it is 
responsible under this contract are those specified in DOE Directive 
6430.1, version in effect on effective date of contract, entitled 
General Design Criteria. The contractor shall comply with these 
mandatory, minimally acceptable requirements for all facility designs 
with regard to any building acquisition, new facility, facility addition 
or alteration or facility lease undertaken as part of the site 
development activities of paragraph (a) above. This includes on-site 
constructed buildings, pre-engineered buildings, plan-fabricated modular 
buildings, and temporary facilities. For existing facilities, original 
design criteria apply to the structure in general; however, additions or 
modifications shall comply with this directive and the associated latest 
editions of the references therein. An exception may be granted for off-
site office space being leased by the contractor on a temporary basis.
    (c) Energy management. The contractor shall manage the facilities 
for which it is responsible under the terms and conditions of this 
contract in an energy efficient manner in accordance with DOE Directive 
4330.2C, version in effect on effective date of contract, entitled In-
House Energy Management. The contractor shall develop a 10-year energy 
management plan for each site with annual reviews and revisions. The 
contractor shall submit an annual report on progress toward achieving 
the goals of the 10-year plan for each individual site, and an energy 
conservation analysis report for each new building or building addition 
project. Any acquisition of utility services by the contractor shall be 
conducted in accordance with 970.0803.
    (d) Subcontract requirements. To the extent the contractor 
subcontracts performance of any of the responsibilities discussed in 
this clause, the subcontract shall contain the requirements of this 
clause relative to the subcontracted responsibilities.
[58 FR 34925, June 30, 1993; 58 FR 43287, Aug. 16, 1993, as amended at 
59 FR 9112, Feb. 25, 1994; 62 FR 2313, Jan. 16, 1997]



970.5204-61  Cost prohibitions related to legal and other proceedings.

    As prescribed in 48 CFR (DEAR) 970.3103(c), insert the following 
clause.

[[Page 501]]

  Cost Prohibitions Related to Legal and Other Proceedings (June 1997)

    (a) Definitions.
    Conviction, as used in this section, means a judgment or conviction 
of a criminal offense by any court of competent jurisdiction, whether 
entered upon a verdict or a plea, including a conviction due to a plea 
of nolo contendere.
    Costs include, but are not limited to, administrative and clerical 
expenses; the cost of legal services, whether performed by in-house or 
private counsel; the costs of the services of accountants, consultants, 
or others retained by the contractor to assist it; all elements of 
compensation, related costs, and expenses of employees, officers and 
directors; and any similar costs incurred before, during, and after 
commencement of a proceeding which bears a direct relationship to the 
proceeding.
    Fraud, as used herein, means
    (i) Acts of fraud or corruption or attempts to defraud the 
Government or to corrupt its agents,
    (ii) Acts which constitute a cause for debarment or suspension under 
FAR 9.406-(2)(a) and FAR 9.407-(2)(a), and
    (iii) Acts which violate the False Claims Act, 31 U.S.C. 3729-3731, 
or the Anti-kickback Act, 41 U.S.C. 51 and 54.
    Penalty does not include restitution, reimbursement, or compensatory 
damages.
    Proceeding includes an investigation.
    (b) Except as otherwise described in this section, costs incurred in 
connection with any proceeding brought by a third party in the name of 
the United States under the False Claims Act, 31 U.S.C. 3730, or costs 
incurred in connection with any criminal, civil, or administrative 
proceeding by the Federal Government, or a State, local, or foreign 
government, are not allowable if the proceeding relates to a violation 
of, or failure to comply with a federal, State, local, or foreign 
statute or regulation by the contractor, and results in any of the 
following dispositions:
    (1) In a criminal proceeding, conviction.
    (2) In a civil or administrative proceeding involving an allegation 
of fraud or similar misconduct, a determination of contractor liability.
    (3) In the case of any civil or administrative proceeding, the 
imposition of a monetary penalty.
    (4) A final decision by an appropriate Federal official to debar or 
suspend the contractor, to rescind or void a contract, or to terminate a 
contract for default by reason of a violation of or failure to comply 
with a law or regulation.
    (5) A disposition by consent or compromise, if the action could have 
resulted in any of the dispositions described in paragraphs (b) (1), 
(2), (3) or (4) of this section.
    (6) Not covered by paragraphs (b)(1) through (5) of this section, 
but where the underlying alleged contractor misconduct was the same as 
that which led to a different proceeding whose costs are unallowable by 
reason of paragraphs (b)(1) through (5) of this section.
    (c)(1) If a proceeding referred to in paragraph (b) of this section 
is commenced by the Federal Government and is resolved by consent or 
compromise pursuant to an agreement entered into by the contractor and 
the Federal Government, then the costs incurred by the contractor in 
connection with such proceeding that are otherwise unallowable under 
paragraph (b) of this section may be allowed to the extent specifically 
provided in such agreement.
    (2) In the event of a settlement of any proceeding brought by a 
third party under the False Claims Act in which the United States did 
not intervene, reasonable costs incurred by the contractor in connection 
with such a proceeding that are not otherwise unallowable by regulation 
or by separate agreement with the United States, may be allowed if the 
contracting officer, in consulation with his or her legal advisor, 
determines that there is very little likelihood that the third party 
would have been successful on the merits.
    (d) If a proceeding referred to in paragraph (b) of this section is 
commenced by a State, local or foreign government, the Contracting 
Officer may allow the costs incurred in such proceeding, provided the 
Procurement Executive determines that the costs were incurred as a 
result of compliance with a specific term or condition of the contract, 
or specific written direction of the Contracting Officer.
    (e) Costs incurred in connection with a proceeding described in 
paragraph (b) of this section, but which are not made unallowable by 
that paragraph, may be allowed by the Contracting Officer only to the 
extent that:
    (1) The total costs incurred are reasonable in relation to the 
activities required to deal with the proceeding and the underlying cause 
of action;
    (2) Payment of the costs incurred, as allowable and allocable 
contract costs, is not prohibited by any other provision(s) of this 
contract;
    (3) The costs are not otherwise recovered from the Federal 
Government or a third party, either directly as a result of the 
proceeding or otherwise; and
    (4) The amount of costs allowed does not exceed 80 percent of the 
total costs incurred and otherwise allowable under the contract. Such 
amount that may be allowed (up to the 80 percent limit) shall not exceed 
the percentage determined by the contracting officer to be appropriate, 
considering the complexity of procurement litigation, generally accepted 
principles governing the award of

[[Page 502]]

legal fees in civil actions involving the United States as a party, and 
such other factors as may be appropriate. The amount of reimbursement 
allowed for legal costs in connection with any proceeding described in 
subparagraph (c)(2) shall be the amount determined to be reasonable by 
the contracting officer but shall not exceed 80 percent of otherwise 
allowable costs incurred. Agreements reached under paragraph (c) of this 
subsection shall be subject to this limitation. If, however, an 
agreement explicitly states the amount of otherwise allowable incurred 
legal fees and limits the allowable recovery to 80 percent or less of 
the stated legal fees, no additional limitation need be applied.
    (f) Contractor costs incurred in connection with the defense of 
suits brought by employees or ex-employees of the contractor under 
section 2 of the Major Fraud Act of 1988, including the cost of all 
relief necessary to make such employee whole, where the contractor was 
found liable or settled, are unallowable.
    (g) Costs which may be unallowable under this clause, including 
directly associated costs, shall be differentiated and accounted for by 
the contractor so as to be separately identifiable. During the pendency 
of any proceeding covered by paragraphs (b) and (f) of this section, the 
Contracting Officer shall generally withhold payment and not authorize 
the use of funds advanced under the contract for the payment of such 
costs. However, the Contracting Officer may, in appropriate 
circumstances, provide for conditional payment upon provision of 
adequate security, or other adequate assurance, and agreements by the 
contractor to repay all unallowable costs, plus interest, if the costs 
are subsequently determined to be unallowable.
[58 FR 61628, Nov. 22, 1993, as amended at 59 FR 9112, Feb. 25, 1994; 62 
FR 34869, June 27, 1997]



970.5204-62  [Reserved]



970.5204-63  Collective bargaining agreements--management and operating contracts.

    As prescribed in 970.2201(b)(5)(ii), insert the following clause:

  Collective Bargaining Agreements--Management and Operating Contracts 
                               (Aug 1993)

    When negotiating collective bargaining agreements applicable to the 
work force under this contract, the Contractor shall use its best 
efforts to ensure such agreements contain provisions designed to assure 
continuity of services. All such agreements entered into during the 
contract period of performance should provide that grievances and 
disputes involving the interpretation or application of the agreement 
will be settled without resorting to strike, lockout, or other 
interruption of normal operations. For this purpose, each collective 
bargaining agreement should provide an effective grievance procedure 
with arbitration as its final step, unless the parties mutually agree 
upon some other method of assuring continuity of operations. As part of 
such agreements, management and labor should agree to cooperate fully 
with the Federal Mediation and Conciliation Service. The contractor 
shall include the substance of this clause in any subcontracts for 
protective services or other services performed on the DOE-owned site 
which will affect the continuity of operation of the facility.
[58 FR 36152, July 6, 1993; 58 FR 43287, Aug. 16, 1993]



970.5204-71  Patent rights--nonprofit management and operating contractors.

    As prescribed at 970.2703, insert the clause at 952.227-11, Patent 
Rights-Retention by the Contractor (Short Form) with the following 
changes:

 Patent Rights-Nonprofit Management and Operating Contractors (Mar 1995)

    1. Replace subparagraph (e)(1) with the following: (e)(1) The 
contractor may request the right to reserve a revocable, nonexclusive, 
royalty-free license throughout the world in each subject invention to 
which the Government obtains title, except if the contractor fails to 
disclose the invention within the times specified in paragraph (c) of 
this clause. When DOE approves such reservation, the contractor's 
license will extend to its domestic subsidiaries and affiliates, if any, 
within the corporate structure of which the contractor is a party and 
includes the right to grant sublicenses of the same scope to the extent 
the contractor was legally obligated to do so at the time the contract 
was awarded. The license is transferable only with the approval of DOE, 
except when transferred to the successor of that part of the 
contractor's business to which the invention pertains.
    2. Add the following paragraphs (m) and (n): (m) Transfer to 
successor contractor. (1) In the event of termination or expiration of 
this contract, the contractor shall transfer any unexpended balance of 
income received relating to intellectual property, in accordance with 
instructions from the contracting officer, to a successor contractor, or 
in the absence of a successor contractor, to such other entity as 
designated by the contracting officer. The contractor shall also 
transfer title, as one package, in all patents and patent applications, 
license agreements, accounts containing royalty revenues from such 
license agreements, including equity

[[Page 503]]

positions in third-party entities, and other intellectual property that 
arose under the performance of this contract, to the successor 
contractor or to the Government, as directed by the contracting officer.
    (2) The Government agrees that the recipient of such title shall 
assume any remaining obligations and liabilities in connection with the 
patents and patent applications.
    (n) Facilities license. In addition to the rights of the parties 
with respect to inventions or discoveries conceived or first actually 
reduced to practice in the course of or under this contract, the 
contractor agrees to and does hereby grant to the Government an 
irrevocable, nonexclusive, paid-up license in and to any inventions or 
discoveries regardless of when conceived or actually reduced to practice 
or acquired by the contractor at any time through completion of this 
contract and which are incorporated or embodied in the construction of 
the facility or which are utilized in the operation of the facility or 
which cover articles, materials, or products manufactured at the 
facility (1) to practice or have practiced by or for the Government at 
the facility, and (2) to transfer such license with the transfer of that 
facility. The acceptance or exercise by the Government of these rights 
shall not prevent the Government at any time from contesting the 
enforceability, validity or scope of, or title to, any rights or patents 
herein licensed.

                             (End of clause)

[60 FR 11824, Mar. 2, 1995]



970.5204-72  Patent rights--profit-making management and operating contractors.

    As prescribed at 970.2703, insert the clause at 952.227-13, Patent 
Rights-Retention by the Government, with the following changes:

 Patent Rights--Profit-Making Management and Operating Contractors (Mar 
                                  1995)

    1. Add the following paragraphs (j) and (k):
    (j) Transfer to successor contractor. (1) In the event of 
termination or expiration of this contract, the contractor shall 
transfer any unexpended balance of income received relating to 
intellectual property, in accordance with instructions from the 
contracting officer, to a successor contractor, or in the absence of a 
successor contractor, to such other entity as designated by the 
contracting officer. The contractor shall also transfer title, as one 
package, in all patents and patent applications, license agreements, 
accounts containing royalty revenues from such license agreements, 
including equity positions in third-party entities, and other 
intellectual property that arose under the performance of this contract, 
to the successor contractor or to the Government, as directed by the 
contracting officer.
    (2) The Government agrees that the recipient of such title shall 
assume any remaining obligations and liabilities in connection with the 
patents and patent applications.
    (k) Facilities License. In addition to the rights of the parties 
with respect to inventions or discoveries conceived or first actually 
reduced to practice in the course of or under this contract, the 
contractor agrees to and does hereby grant to the Government an 
irrevocable, nonexclusive, paid-up license in and to any inventions or 
discoveries regardless of when conceived or actually reduced to practice 
or acquired by the contractor at any time through completion of this 
contract and which are incorporated or embodied in the construction of 
the facility or which are utilized in the operation of the facility or 
which cover articles, materials, or products manufactured at the 
facility (1) to practice or have practiced by or for the Government at 
the facility, and (2) to transfer such license with the transfer of that 
facility. The acceptance or exercise by the Government of these rights 
shall not prevent the Government at any time from contesting the 
enforceability, validity or scope of, or title to, any rights or patents 
herein licensed.

                             (End of clause)

[60 FR 11824, Mar. 2, 1995]



970.5204-73  Notice regarding options.

    As prescribed in 48 CFR (DEAR) 970.1702-2(a), insert the following 
provision:

                  Notice Regarding Options (June 1996)

    The contract resulting from this solicitation is expected to include 
one or more options to extend the term of the contract. Exercise of any 
option to extend the term of contract will be at the unilateral right of 
the Department of Energy. The contractor's performance under the basic 
contract, including any previously exercised options, will be among the 
significant considerations in the Department's decision to exercise any 
option.
[61 FR 32587, June 24, 1996]



970.5204-74  Option to extend the term of the contract.

    As prescribed in 48 CFR (DEAR) 970.1702-2(b), insert the following 
clause:

[[Page 504]]

          Option to Extend the Term of the Contract (June 1996)

    (a) The Department of Energy may unilaterally extend the term of 
this performance-based management contract by written notice to the 
contractor within [Insert the period of time in which the contracting 
officer has to exercise the option]; provided, that the Department of 
Energy shall give the contractor a preliminary written notice of its 
intent to extend at least twelve (12) months before the basic term of 
the contract expires. The preliminary notice does not commit the 
Department of Energy to an extension.
    (b) The option(s) to extend the contract is identified in [Specify 
section of contract and clause number and name] of the contract. The 
Department of Energy may exercise any, or all, of the options identified 
in the contract. The total duration of this contract, including the 
exercise of any option(s) under this clause, shall not exceed 120 
months.
[61 FR 32587, June 24, 1996]



970.5204-75  Preexisting conditions.

    As prescribed in 48 CFR (DEAR) 970.3103(d), insert the following 
clause.

                   Preexisting Conditions (June 1997)

    (a) The Department of Energy agrees to reimburse the contractor, and 
the contractor shall not be held responsible, for any liability 
(including without limitation, a claim involving strict or absolute 
liability and any civil fine or penalty), expense, or remediation cost, 
but limited to those of a civil nature, which may be incurred by, 
imposed on, or asserted against the contractor arising out of any 
condition, act, or failure to act which occurred before the contractor 
assumed responsibility on [Insert date contract began]. To the extent 
the acts or omissions of the contractor cause or add to any liability, 
expense or remediation cost resulting from conditions in existence prior 
to [Insert date contract began], the contractor shall be responsible in 
accordance with the terms and conditions of this contract.
    (b) The obligations of the Department of Energy under this clause 
are subject to the availability of appropriated funds. Alternate I. As 
prescribed in 48 CFR (DEAR) 970.3103(d), substitute the following 
paragraph (a):
    (a) Any liability, obligation, loss, damage, claim (including 
without limitation, a claim involving strict or absolute liability), 
action, suit, civil fine or penalty, cost, expense or disbursement, 
which may be incurred or imposed, or asserted by any party and arising 
out of any condition, act or failure to act which occurred before 
[Insert date this clause was included in contract], in conjunction with 
the management and operation of [Insert name of facility], shall be 
deemed incurred under Contract No. [Insert number of prior contract].
    Alternate II. As prescribed in 48 CFR (DEAR) 970.3103(d), include 
the following paragraph (c):
    (c) The contractor has the duty to inspect the facilities and sites 
and timely identify to the contracting officer those conditions which it 
believes could give rise to a liability, obligation, loss, damage, 
penalty, fine, claim, action, suit, cost, expense, or disbursement or 
areas of actual or potential noncompliance with the terms and conditions 
of this contract or applicable law or regulation. The contractor has the 
responsibility to take corrective action, as directed by the contracting 
officer and as required elsewhere in this contract.
[62 FR 34869, June 27, 1997]



970.5204-76  Make-or-buy plan.

    As prescribed in 48 CFR (DEAR) 970.1507-3, insert the following 
clause:

                      Make-or-Buy Plan (June 1997)

    (a) Definitions.
    Buy item means a work activity, supply, or service to be produced or 
performed by an outside source, including a subcontractor or an 
affiliate, subsidiary, or division of the contractor.
    Make item means a work activity, supply, or service to be produced 
or performed by the contractor using its personnel and other resources 
at the Department of Energy facility or site.
    Make-or-buy plan means a contractor's written program for the 
contract that identifies work efforts or requirements that either are 
``make items'' or ``buy items.''
    (b) Make-or-buy plan. The contractor shall develop and implement a 
make-or-buy plan that establishes a preference for providing supplies 
and services on a least-cost basis, subject to any specific make or buy 
criteria identified in the contract or otherwise provided by the 
contracting officer. In developing and implementing its make-or-buy 
plan, the contractor agrees to assess subcontracting opportunities and 
implement subcontracting decisions in accordance with the following:
    (1) The contractor shall conduct internal productivity improvement 
and cost-reduction programs so that in-house performance options can be 
made more efficient and cost-effective.
    (2) The contractor shall consider subcontracting opportunities with 
the maximum practicable regard for open communications with potentially 
affected employees and their representatives. Similarly, a contractor 
shall communicate its plans, activities, cost-benefit analyses, and 
decisions

[[Page 505]]

to those stakeholders, including representatives of the community and 
local businesses, likely to be affected by such actions.
    (c) Submission and approval. For new contract awards, the contractor 
shall submit an initial make-or-buy plan, for approval, within 180 days 
after contract award. If the existing contract is to be extended, the 
contractor shall submit a make-or-buy plan for review and approval at 
least 90 days prior to the commencement of the negotiations for the 
extension. The following documentation shall be prepared and submitted:
    (1) A description of the each work item, and if appropriate, the 
identification of the associated Work Authorization or Work Breakdown 
Structure element;
    (2) The categorization of each work item as ``must make,'' ``must 
buy,'' or ``can make or buy,'' with the reasons for such categorization 
in consideration of the program specific make or buy criteria (including 
least cost considerations). For non-core capabilities categorized as 
``must make,'' a cost/benefit analysis must be performed for each item 
if:
    (i) The contractor is not the least-cost performer, and
    (ii) A program specific make-or-buy criterion does not otherwise 
justify a ``must make'' categorization;
    (3) A decision to either ``make'' or ``buy'' in consideration of the 
program specific make or buy criteria (including least cost 
considerations) for work effort categorized as ``can make or buy'';
    (4) Identification of potential suppliers and subcontractors, if 
known, and their location and size status;
    (5) A recommendation to defer a make or buy decision where 
categorization of an identifiable work effort is impracticable at the 
time of initial development of the plan and a schedule for future re-
evaluation;
    (6) A description of the impact of a change in current practice of 
making or buying on the existing work force; and
    (7) Any additional information appropriate to support and explain 
the plan.
    (d) Conduct of operations. Once a make-or-buy plan is approved, the 
contractor shall perform in accordance with the plan.
    (e) Changes to the make-or-buy plan. The make-or-buy plan 
established in accordance with paragraph (b) of this clause shall remain 
in effect for the term of the contract, unless:
    (1) A lesser period is provided either for the total plan or for 
individual items or work effort;
    (2) The circumstances supporting the make-or-buy decisions change, 
or
    (3) New work is identified.
    At least annually, the contractor shall review its approved make-or-
buy plan to ensure that it reflects current conditions. Changes to the 
approved make-or-buy plan shall be submitted in advance of the effective 
date of the proposed change in sufficient time to permit evaluation and 
review. Changes shall be submitted in accordance with the instructions 
provided by the contracting officer. Modification of the make-or-buy 
plan to incorporate proposed changes or additions shall be effective 
upon the contractor's receipt of the contracting officer's written 
approval.
[62 FR 34870, June 27, 1997]



970.5204-77  Workforce Restructuring Under Section 3161 of the National Defense Authorization Act for Fiscal Year 1993.

    As prescribed in 48 CFR (DEAR) 970.2602-2, insert the following 
clause.

   Workforce Restructuring Under Section 3161 of the National Defense 
           Authorization Act for Fiscal Year 1993 (June 1997)

    (a) Consistent with the objectives of Section 3161 of the National 
Defense Authorization Act for Fiscal Year 1993, 42 U.S.C. 7274h, in 
instances where the Department of Energy has determined that a change in 
workforce at a Department of Energy Defense Nuclear Facility is 
necessary, the contractor agrees to (1) comply with the Department of 
Energy Workforce Restructuring Plan for the facility, if applicable, and 
(2) use its best efforts to accomplish workforce restructuring or 
displacement so as to mitigate social and economic impacts.
    (b) The requirements of this clause shall be included in 
subcontracts at any tier (except subcontracts for commercial items 
pursuant to 41 U.S.C. 403) expected to exceed $500,000.
[62 FR 34870, June 27, 1997]



970.5204-78  Laws, regulations, and DOE directives.

    As prescribed in 48 CFR (DEAR) 970.0470-2, insert the following 
clause.

            Laws, Regulations, and DOE Directives (June 1997)

    (a) In performing work under this contract, the contractor shall 
comply with the requirements of applicable Federal, State, and local 
laws and regulations (including DOE regulations), unless relief has been 
granted in writing by the appropriate regulatory agency. A List of 
Applicable Laws and Regulations (List A) may be appended to this 
contract for information purposes. Omission of any applicable law or 
regulation from List A does not affect the obligation of the contractor 
to comply with such law or regulation pursuant to this paragraph.
    (b) In performing work under this contract, the contractor shall 
comply with the requirements of those Department of Energy directives, 
or parts thereof, identified in the

[[Page 506]]

List of Applicable Directives (List B) appended to this contract. Except 
as otherwise provided for in paragraph (c) of this clause, the 
contracting officer may, from time to time and at any time, revise List 
B by unilateral modification to the contract to add, modify, or delete 
specific requirements. Prior to revising List B, the contracting officer 
shall notify the contractor in writing of the Department's intent to 
revise List B and provide the contractor with the opportunity to assess 
the effect of the contractor's compliance with the revised list on 
contract cost and funding, technical performance, and schedule; and 
identify any potential inconsistencies between the revised list and the 
other terms and conditions of the contract. Within 30 days after receipt 
of the contracting officer's notice, the contractor shall advise the 
contracting officer in writing of the potential impact of the 
contractor's compliance with the revised list. Based on the information 
provided by the contractor and any other information available, the 
contracting officer shall decide whether to revise List B and so advise 
the contractor not later than 30 days prior to the effective date of the 
revision of List B. The contractor and the contracting officer shall 
identify and, if appropriate, agree to any changes to other contract 
terms and conditions, including cost and schedule, associated with the 
revision of List B pursuant to the clause entitled, Changes, of this 
contract.
    (c) Environmental, safety, and health (ES&H) requirements 
appropriate for work conducted under this contract may be determined by 
a DOE approved process to evaluate the work and the associated hazards 
and identify an appropriately tailored set of standards, practices, and 
controls, such as a tailoring process included in a DOE approved Safety 
Management System implemented under 48 CFR (DEAR) 970.5204-2. When such 
a process is used, the set of tailored ES&H requirements, as approved by 
DOE pursuant to the process, shall be incorporated into List B as 
contract requirements with full force and effect. These requirements 
shall supersede, in whole or in part, the contractual environmental, 
safety, and health requirements previously made applicable to the 
contract by List B. If the tailored set of requirements identifies an 
alternative requirement varying from an ES&H requirement of an 
applicable law or regulation, the contractor shall request an exemption 
or other appropriate regulatory relief specified in the regulation.
    (d) The contractor is responsible for compliance with the 
requirements made applicable to this contract, regardless of the 
performer of the work. The contractor is responsible for flowing down 
the necessary provisions to subcontracts at any tier to which the 
contractor determines such requirements apply.
[62 FR 34870, June 27, 1997]



970.5204-79  Access to and ownership of records.

    As prescribed in 48 CFR (DEAR) 970.0407-3, insert the following 
clause.

             Access to and Ownership of Records (June 1997)

    (a) Government-owned records. Except as provided in paragraph (b) of 
this clause, all records acquired or generated by the contractor in its 
performance of this contract shall be the property of the Government and 
shall be delivered to the Government or otherwise disposed of by the 
contractor either as the contracting officer may from time to time 
direct during the process of the work or, in any event, as the 
contracting officer shall direct upon completion or termination of the 
contract.
    (b) Contractor-owned records. The following records are considered 
the property of the contractor and are not within the scope of paragraph 
(a) of this clause. [The contracting officer shall identify which of the 
following categories of records will be included in the clause.]
    (1) Employment-related records (such as workers' compensation files; 
employee relations records, records on salary and employee benefits; 
drug testing records, labor negotiation records; records on ethics, 
employee concerns, and other employee related investigations conducted 
under an expectation of confidentiality; employee assistance program 
records; and personnel and medical/health-related records and similar 
files), except for those records described by the contract as being 
maintained in Privacy Act systems of records.
    (2) Confidential contractor financial information, and 
correspondence between the contractor and other segments of the 
contractor located away from the DOE facility (i.e., the contractor's 
corporate headquarters);
    (3) Records relating to any procurement action by the contractor, 
except for records that under 48 CFR (DEAR) 970.5204-9, Accounts, 
Records, and Inspection, are described as the property of the 
Government; and
    (4) Legal records, including legal opinions, litigation files, and 
documents covered by the attorney-client and attorney work product 
privileges; and
    (5) The following categories of records maintained pursuant to the 
technology transfer clause of this contract:

[[Page 507]]

    (i) Executed license agreements, including exhibits or appendices 
containing information on royalties, royalty rates, other financial 
information, or commercialization plans, and all related documents, 
notes and correspondence.
    (ii) The contractor's protected Cooperative Research and Development 
Agreement (CRADA) information and appendices to a CRADA that contain 
licensing terms and conditions, or royalty or royalty rate information.
    (iii) Patent, copyright, mask work, and trademark application files 
and related contractor invention disclosures, documents and 
correspondence, where the contractor has elected rights or has 
permission to assert rights and has not relinquished such rights or 
turned such rights over to the Government.
    (c) Contract completion or termination. In the event of completion 
or termination of this contract, copies of any of the contractor-owned 
records identified in paragraph (b) of this clause, upon the request of 
the Government, shall be delivered to DOE or its designees, including 
successor contractors. Upon delivery, title to such records shall vest 
in DOE or its designees, and such records shall be protected in 
accordance with applicable federal laws (including the Privacy Act), as 
appropriate.
    (d) Inspection, copying, and audit of records. All records acquired 
or generated by the contractor under this contract in the possession of 
the contractor, including those described at paragraph (b) of this 
clause, shall be subject to inspection, copying, and audit by the 
Government or its designees at all reasonable times, and the contractor 
shall afford the Government or its designees reasonable facilities for 
such inspection, copying, and audit; provided, however, that upon 
request by the contracting officer, the contractor shall deliver such 
records to a location specified by the contracting officer for 
inspection, copying, and audit. The Government or its designees shall 
use such records in accordance with applicable federal laws (including 
the Privacy Act), as appropriate.
    (e) Applicability. Paragraphs (b), (c), and (d) of this clause apply 
to all records without regard to the date or origination of such 
records.
    (f) Records retention standards. Special records retention 
standards, described at DOE Order 1324.5B, Records Management Program 
and DOE Records Schedules (version in effect on effective date of 
contract), are applicable for the classes of records described therein, 
whether or not the records are owned by the Government or the 
contractor. In addition, the contractor shall retain individual 
radiation exposure records generated in the performance of work under 
this contract until DOE authorizes disposal. The Government may waive 
application of these record retention schedules, if, upon termination or 
completion of the contract, the Government exercises its right under 
paragraph (c) of this clause to obtain copies and delivery of records 
described in paragraphs (a) and (b) of this clause.
    (g) Flow down. The contractor shall include the requirements of this 
clause in all subcontracts that are of a cost-reimbursement type if any 
of the following factors is present:
    (1) The value of the subcontract is greater than $2 million (unless 
specifically waived by the contracting officer);
    (2) The contracting officer determines that the subcontract is, or 
involves, a critical task related to the contract; or
    (3) The subcontract includes 48 CFR (DEAR) 970.5204-2, Integration 
of Environment, Safety, and Health into Work Planning and Execution, or 
similar clause.
[62 FR 34871, June 27, 1997]



970.5204-80  Overtime management.

    As prescribed in 48 CFR (DEAR) 970.2275-2, insert the following 
clause:

                     Overtime Management (June 1997)

    (a) The contractor shall maintain adequate internal controls to 
ensure that employee overtime is authorized only if cost effective and 
necessary to ensure performance of work under this contract.
    (b) The contractor shall notify the contracting officer when in any 
given year it is likely that overtime usage as a percentage of payroll 
may exceed 4%.
    (c) The contracting officer may require the submission, for 
approval, of a formal annual overtime control plan whenever contractor 
overtime usage as a percentage of payroll has exceeded, or is likely to 
exceed, 4%, or if the contracting officer otherwise deems overtime 
expenditures excessive. The plan shall include, at a minimum:
    (1) An overtime premium fund (maximum dollar amount);
    (2) Specific controls for casual overtime for non-exempt employees;
    (3) Specific parameters for allowability of exempt overtime;
    (4) An evaluation of alternatives to the use of overtime; and
    (5) Submission of a semi-annual report that includes for exempt and 
non-exempt employees:
    (i) Total cost of overtime;
    (ii) Total cost of straight time;
    (iii) Overtime cost as a percentage of straight-time cost;
    (iv) Total overtime hours;
    (v) Total straight-time hours; and
    (vi) Overtime hours as a percentage of straight-time hours.
[62 FR 34871, June 27, 1997]

[[Page 508]]



        Subpart 970.70--Use of DOE Facilities for Work for Others



970.7000  Mission-oriented solicitation.

    Contractors shall be required to promptly advise the DOE contracting 
officer of any advance notices of, or solicitations for, requirements 
which would logically involve DOE facilities or resources operated or 
managed by the contractor, received from other agencies pursuant to FAR 
34.005. Management and operating contracts shall provide that the 
contractor shall not respond or otherwise propose to participate in 
response to the requirements of such solicitations unless the contractor 
shall have first obtained the written approval of the DOE manager of the 
field activity having cognizance over the contract. Such approval shall 
not be given except in compliance with DOE directives and with the 
concurrence of the appropriate Senior Program Official.



     Subpart 970.71--Management and Operating Contractor Purchasing

    Source:  53 FR 24232, June 27, 1988, unless otherwise noted.



970.7101  General.

    (a) The Department of Energy contracts for the management and 
operation of DOE facilities, the design and production of nuclear 
weapons, energy research and development, and the performance of other 
services. These management and operating (M&O) contractors have been 
selected for their technical and managerial expertise and are expected 
to bring to bear these technical and managerial skills to accomplish the 
significant Federal mission(s) described in their contracts with, and 
work plans approved by, DOE.
    (b) Purchasing done by management and operating contractors is one 
area in which the particular skills of the contractors will be brought 
to bear in order to more readily accomplish the contractors' assigned 
missions. The contracting procedures of the contractor's organization, 
therefore, form the basis for the development of a purchasing system and 
methods that will comply with its contract with DOE and this subpart.
[53 FR 24232, June 27, 1988; 54 FR 1288, Jan. 12, 1989, as amended at 60 
FR 28741, June 2, 1995]



970.7102  DOE responsibility.

    (a) In the Department of Energy, overall responsibility for the 
oversight of the performance of management and operating contractors, 
including their purchasing activities, rests with the cognizant DOE 
contracting activity and, in particular, the Head of the Contracting 
Activity (HCA). Contracting officers are responsible for management and 
operating contractors' conformance with this subpart and their 
contracts, and for determining whether those purchasing activities 
provide timely and effective support to DOE programs.
    (b) In carrying out their overall responsibilities, HCAs shall:
    (1) Require management and operating contractors to maintain written 
descriptions of their individual purchasing systems and methods and 
further require that, upon award or extension of the contract, the 
entire written description be submitted to the contracting officer for 
review and acceptance;
    (2) Require that any changes to the management and operating 
contractor's written description having any substantive impact upon the 
contractor's purchasing system and methods be submitted to the 
contracting officer for review and acceptance prior to issuance;
    (3) Ensure review of individual purchasing actions of certain types 
or above stated dollar levels by the contracting officer pursuant to 48 
CFR (FAR) 44.2 or as set forth in the contractor's approved system and 
methods; and
    (4) Ensure that periodic appraisals (e.g. Contractor Purchasing 
System Review (CPSR) and Surveillance Review) of the contractor's 
management of all facets of the purchasing function are performed by the 
contracting officer in accordance with established policies. (See 
970.7103).
    (c) In performing the reviews required by paragraphs (b) (1) and (2) 
and the appraisals of paragraph (b)(4) of this section, HCAs shall 
assure that contracting officers determine that the

[[Page 509]]

contractors' written systems and methods are consistent with this 
subpart and the provisions of their contracts.
[53 FR 24232, June 27, 1988, as amended at 59 FR 9112, Feb. 25, 1994; 60 
FR 28741, June 2, 1995]



970.7103  Contractor purchasing system.

    The following shall apply to the purchasing systems of management 
and operating contractors:
    (a) The objective of a management and operating contractor's 
purchasing system is to deliver to its customers on a timely basis those 
best value products and services necessary to accomplish the purposes of 
the Government's contract. To achieve this objective, contractors are 
expected to use their experience, expertise and initiative consistent 
with this subpart.
    (b) The purchasing systems and methods used by management and 
operating contractors shall be well-defined, consistently applied, and 
shall follow purchasing practices appropriate for the requirement and 
dollar value of the purchase. It is anticipated that purchasing 
practices and procedures will vary among contractors and according to 
the type and kinds of purchases to be made.
    (c) Contractor purchases are not Federal procurements, and are not 
directly subject to the Federal Acquisition Regulations in 48 CFR. 
Nonetheless, certain Federal laws, Executive Orders, and regulations may 
affect contractor purchasing, as required by statute, regulation, or 
contract terms and conditions.
    (d) Contractor purchasing systems shall identify and apply the best 
in commercial purchasing practices and procedures (although nothing 
precludes the adoption of Federal procurement practices and procedures) 
to achieve system objectives. Where specific requirements do not 
otherwise apply, the contractor purchasing system shall provide for 
appropriate measures to ensure the:
    (1) Acquisition of quality products and services at fair and 
reasonable prices;
    (2) Use of capable and reliable subcontractors who either
    (i) Have track records of successful past performance, or
    (ii) Can demonstrate a current superior ability to perform;
    (3) Minimization of acquisition lead-time and administrative costs 
of purchasing;
    (4) Use of effective competitive techniques;
    (5) Reduction of performance risks associated with subcontractors, 
and facilitation of quality relationships which can include techniques 
such as partnering agreements, ombudsmen, and alternative disputes 
procedures;
    (6) Use of self-assessment and benchmarking techniques to support 
continuous improvement in purchasing;
    (7) Maintenance of the highest professional and ethical standards; 
and
    (8) Maintenance of file documentation appropriate to the value of 
the purchase and which is adequate to establish the propriety of the 
transaction and the price paid.
[60 FR 28741, June 2, 1995]



970.7105  Purchasing from contractor-affiliated sources.

    (a) A management and operating contractor may purchase from sources 
affiliated with the contractor (any division, subsidiary, or affiliate 
of the contractor or its parent company) in the same manner as from 
other sources, provided:
    (1) The management and operating contractor's purchasing function is 
independent of the proposed contractor-affiliated source;
    (2) The same terms and conditions would apply if the purchase were 
from a third party;
    (3) Award is made in accordance with policies and procedures 
designed to permit effective competition which have been approved by the 
contracting officer. (This requirement for competition shall not 
preclude acquisition of technical services from contractor-affiliated 
entities where those entities have a special expertise, and the basis 
therefor is documented.); and
    (4) The award is legally enforceable where the entities are 
separately incorporated.
    (b) Subcontracts for performance of contract work itself (as 
distinguished

[[Page 510]]

from the purchase of supplies and services needed in connection with the 
performance of work) require DOE authorization and may involve an 
adjustment of the contractor's fee, if any. If the management and 
operating contractor seeks authorization to have some part of the 
contract work performed by a contractor-affiliated source, and that 
contractor's performance of that work was a factor in the negotiated 
fee, DOE approval would normally require:
    (1) That the contractor-affiliated source perform such work without 
fee or profit, or
    (2) An equitable downward adjustment to the management and operating 
contractor's fee, if any.
    (c) Determination on cost of money allowance as prescribed at FAR 
31.205-10 shall be treated as follows:
    (1) When a purchase from a contractor-affiliated source results from 
competition and is in accord with provisions and conditions of 
paragraphs (a)(1) through (a)(4) of this section, the contractor-
affiliated source may include cost of money as an allowable element of 
the costs of its goods or services supplied to the contractor; provided:
    (i) The purchase is based on cost as set forth in 970.3102-15 and
    (ii) The cost of money amount is computed in accordance with FAR 
31.205-10 and related procedures (see 970.30).
    (2) When a purchase from a contractor-affiliated source is made non-
competitively, cost of money shall not be considered an allowable 
element of the cost of the contractor-affiliated source purchase.
[53 FR 24232, June 27, 1988, as amended at 62 FR 2313, Jan. 16, 1997]



970.7108  Review and approval.

    (a) The Heads of Contracting Activities shall establish thresholds 
by subcontract type and dollar level for the review and approval of 
proposed subcontracting actions by each management and operating 
contractor under their cognizance. Such thresholds may not exceed the 
authority delegated to the Head of the Contracting Activity by the 
Procurement Executive. In establishing these review and approval 
thresholds, the Heads of Contracting Activities should consider such 
factors as the following:
    (1) The nature of work to be performed under the management and 
operating contract;
    (2) The size, experience, ability, reliability, and organization of 
the management and operating contractor's purchasing function;
    (3) The internal controls, procedures, and organizational stature of 
the management and operating contractor's purchasing function; and
    (4) Policies with respect to such reviews and approvals established 
by the Procurement Executive.
    (b) Prior approval shall be required for the subcontracting of any 
work a contractor is obligated to perform under a contract entered into 
under section 41, entitled Production of Special Nuclear Material, of 
the Atomic Energy Act of 1954, as amended.
    (c) The Heads of Contracting Activities shall take such action as 
may be required to insure compliance with the procedure for purchasing 
from contractor-affiliated sources or the purchase of specific items, or 
classes of items, which by the terms of the contract may require DOE 
approval.
    (d) The Heads of Contracting Activities may raise or lower the 
review and approval thresholds established pursuant to paragraph (a) of 
this section at any time. Such action may be considered upon the 
periodic review of the contractor's purchasing system, but in any case 
those adjusted thresholds may not exceed the approval authority 
delegated to the Head of the Contracting Activity by the Procurement 
Executive.
    (e) Department of Energy approvals of specific proposed purchases 
pursuant to this subpart shall communicate that such approval does not 
relieve the management and operating contractor of any obligation under 
its prime contract with DOE; is given without prejudice to any rights or 
claims of the Government thereunder; creates no obligation on the part 
of the Government to the subcontractor, and is not a predetermination of 
the allowability of costs to be incurred under the subcontract.

[[Page 511]]

    (f) Contracting officers shall assure that management and operating 
contractors establish and maintain subcontract files which contain those 
documents essential to present an accurate and adequate record of all 
purchasing transactions.
    (g) Contracting officers shall assure that management and operating 
contractors document purchases in writing, setting forth the information 
and data used in determining that the purchases are in the best interest 
of the Government. The scope and detail of this documentation shall be 
consistent with the nature, dollar value, and complexity of the 
purchase.
    (h) The Heads of Contracting Activities will assure that the 
contracting activity establishes and maintains files of the documents 
associated with the review and approval of subcontract actions subject 
to DOE review and approval. Those files shall include, among other 
necessary documentation, an appraisal of the proposed action by the 
contracting activity and a copy of the approving or disapproving 
document forwarded to the management and operating contractor, 
containing a listing of any deficiencies, a listing of any required 
corrective actions, any suggestions, or other relevant comments.
[53 FR 24232, June 27, 1988, as amended at 59 FR 9112, Feb. 25, 1994]



970.7109  Advance notification.

    (a) Pursuant to section 304(b) of the Federal Property and 
Administrative Service Act of 1949, as amended (41 U.S.C. 254(b)) 
contracting officers shall assure that the written description of the 
management and operating contractor's purchasing system and methods 
provides for advance notice to the DOE contracting officer of the 
proposed award of the following specified types of subcontracts, except 
as stated in paragraph (b) of this section:
    (1) Cost reimbursement-type subcontracts of any award value; and
    (2) Fixed price-type subcontracts which exceed $25,000; and
    (3) Purchases from contractor-affiliated sources over a value 
established by the HCA.
    (b) Pursuant to section 602(d)13 of the Act (40 U.S.C. 474(13)) 
referred to in paragraph (a) of this section, the advance notification 
requirement for the types of purchases listed in paragraphs (a) (1) and 
(2) of this section shall not apply to subcontracts relating to 
functions derived from the Atomic Energy Commission.
    (c) The advance notice shall contain, as a minimum, a description of 
work, estimated cost, type of contract or reimbursement provisions, and 
extent of competition, or justification for a noncompetitive purchase 
procurement. The contracting officer may at any time request additional 
information that must be furnished promptly and prior to award of the 
subcontract.



970.7110  Nuclear material transfers.

    (a) Management and operating contractors, in preparing contracts or 
other agreements in which monetary payments or credits depend on the 
quantity and quality of nuclear material, shall be required to assure 
that each such contract or agreement contains a:
    (1) Description of the material to be transferred;
    (2) Provision specifying the method by which the quantities are to 
be measured and reported;
    (3) Provision specifying the procedures to be used in resolving any 
differences arising as a result of such measurements;
    (4) Provision for the use of an independent third party as an umpire 
to settle unresolved differences in the analytical samples; and
    (5) Provision specifying in detail which party shall bear the costs 
of resolving a difference and what constitutes such costs.
    (b) The provisions providing for resolution of measurement 
differences must be such that resolution is always accomplished, while 
at the same time minimizing any advantage one party may have over the 
other.



                  Subpart 970.72--Facilities Management



970.7201  Policy.

    Contractors managing DOE facilities shall be required to comply with 
the DOE Directives applicable to facilities management. To accomplish 
this, all

[[Page 512]]

management and operating contracts which include contractor management 
of a DOE-owned facility shall contain the clause at 970.5204-60, 
Facilities management, specifying the Directives applicable to the 
contractual situation at the DOE facility involved.
[58 FR 34926, June 30, 1993]



                   Subpart 970.73-Technology Transfer

    Source:  60 FR 66515, Dec. 22, 1995, unless otherwise noted.



970.7310  General.

    This subpart prescribes policies and procedures for implementing the 
National Competitiveness Technology Transfer Act of 1989. The Act 
required that technology transfer be established as a mission of each 
Government-owned laboratory operated under contract by a non-Federal 
entity. The National Defense Authorization Act for Fiscal Year 1994 
expanded the definition of laboratory to include weapon production 
facilities that are operated for national security purposes and are 
engaged in the production, maintenance, testing, or dismantlement of a 
nuclear weapon or its components.



970.7320  Policy.

    All new awards for or extensions of existing DOE laboratory or 
weapon production facility management and operating contracts shall have 
technology transfer, including authorization to award Cooperative 
Research and Development Agreements (CRADAs), as a laboratory or 
facility mission under Section 11(a)(1) of the Stevenson-Wydler 
Technology Innovation Act of 1980, as amended. A management and 
operating contractor for a facility not deemed to be a laboratory or 
weapon production facility may be authorized on a case-by-case basis to 
support the DOE technology transfer mission including, but not limited 
to, participating in CRADAs awarded by DOE laboratories and weapon 
production facilities.



970.7330  Contract clause.

    (a) The contracting officer shall insert the clause at 970.5204-40, 
Technology transfer mission, in each solicitation for a new or an 
extension of an existing laboratory or weapon production facility 
management and operating contract.
    (b) If the contractor is a nonprofit organization or small business 
eligible under 35 U.S.C. 200 et seq., to receive title to any inventions 
under the contract and proposes to fund at private expense the 
maintaining, licensing, and marketing of the inventions, the contracting 
officer shall use the basic clause with its Alternate I.
    (c) The contracting officer may substitute the Alternate II phrase 
``weapon production facility'' wherever the word ``laboratory'' appears 
in the clause where the facility is operated for national security 
purposes and engaged in the production, maintenance, testing, or 
dismantlement of a nuclear weapon or its components.

[[Page 513]]



                 CHAPTER 10--DEPARTMENT OF THE TREASURY




                          (Parts 1000 to 1099)

  --------------------------------------------------------------------

             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
Part                                                                Page
1033            Protests, disputes, and appeals.............         514

[[Page 514]]



             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS





PART 1033--PROTESTS, DISPUTES, AND APPEALS--Table of Contents




                        Subpart 1033.1--Protests

1033.103  Protests to the Agency.

                         Subpart 1033.2--Appeals

1033.270  Treasury contract appeals.

    Authority:  41 U.S.C. 418b (a) and (b), as delegated by Department 
of the Treasury Order 101-30 and Treasury Directive 12-11.



                        Subpart 1033.1--Protests



1033.103  Protests to the Agency.

    (a) Policy. It is the Department's policy to resolve protests in an 
informal manner whenever possible. Protesters are strongly encouraged to 
address their concerns to the contracting officer prior to resorting to 
litigation or other formal, external means of resolution. The objectives 
of the following procedures are to resolve agency protests effectively, 
to help build confidence in the Department's procurement system, to 
reduce the need to file protests at GAO or GSBCA, and to provide both 
the Department and the protester maximum information regarding their 
respective positions.
    (b) Procedures. (1) Agency protest may be submitted by interested 
parties to the contracting officer, who will normally be designated in 
FAR provision 52.233-2 of the solicitation.
    (2) Protests based on alleged improprieties in a solicitation which 
are apparent prior to bid opening or the closing date for receipt of 
initial proposals shall be filed prior to bid opening or the closing 
date for receipt of initial proposals. In negotiated acquisitions, 
alleged improprieties which do not exist in the initial solicitation but 
which are subsequently incorporated into the solicitation must be 
protested not later than the next closing date for receipt of proposals 
following the incorporation.
    (3) In cases other than those covered in paragraph (b)(2) of this 
section, protests shall be filed not later than 10 working days after 
the basis of protest is known or should have been known, whichever is 
earlier.
    (4) Protests shall be in writing and shall include, as a minimum, 
the following information:
    (i) Name, address, and telephone number of the protestor;
    (ii) Solicitation or contract number;
    (iii) Detailed statement of the legal and factual grounds for the 
protest, including copies of relevant documents;
    (iv) Request for a ruling by the contracting officer to whom the 
protest is submitted;
    (v) Statement as to the form of relief requested.
    (5) Protest submissions shall be concise, logically arranged, and 
state sufficient grounds of protest. Failure to comply with any of the 
above requirements may be grounds for dismissal of the protest. A 
protester may request an informal conference with the contracting 
officer, which may be granted at the latter's sole discretion.
    (6) Upon receipt of an agency protest, the contracting officer 
shall:
    (i) Immediately notify legal counsel and the Departmental Office of 
Procurement (MMK) and provide each with a copy of the protest;
    (ii) Prepare a report as prescribed in FAR 33.104(a)(2), except 
that, if the contract action or contract performance continues after 
receipt of the protest, the report shall include any determination 
prescribed in FAR 33.103(a) or 1033.103(b)(9);
    (iii) Obtain review of the protest response by legal counsel and 
forward the protest response for MMK review and approval at least three 
working days prior to the due date; and
    (iv) Ensure that the protest response is received by the protester 
no later than 25 working days after receipt of the protest.
    (7) If the contracting officer and the protester agree on corrective 
action, a report is not required; however, in addition to amending the 
solicitation or taking other corrective action, the contracting officer 
shall inform the protester in writing of the proposed corrective action 
and shall obtain from

[[Page 515]]

the protester a written notice withdrawing the protest. A copy of this 
notice and any amendment shall be provided to MMK.
    (8) If a written protest before award has been lodged with the 
contracting officer, only the bureau chief procurement officer may make 
the determination described in FAR 33.103(a). Prior to making an award 
of a contract under the circumstances in FAR 33.103(a), the advice of 
legal counsel shall be obtained.
    (9) If a written protest after award has been lodged with the 
contracting officer, the bureau chief procurement officer may authorize 
contract performance notwithstanding the pending protest if he or she 
makes a written determination that (i) performance of the contract is in 
the Government's best interest, or (ii) urgent and compelling 
circumstances significantly affecting interests of the United States do 
not permit waiting for the protest decision. A copy of this 
determination shall be forwarded to MMK.

(Approved by the Office of Management and Budget under control number 
1505-0107)

[53 FR 12771, Apr. 19, 1988]



                         Subpart 1033.2--Appeals



1033.270  Treasury contract appeals.

    The General Services Administration Board of Contract Appeals has 
been designated to serve as the authorized representative of the 
Secretary of the Treasury in hearing, considering, and determining all 
appeals of decisions of contracting officers filed by contractors 
pursuant to Subpart 33.2 of the FAR (other than contracts of the 
Comptroller of the Currency). Where ``agency Board of Contract Appeal'' 
appears in FAR Subpart 33.2 this shall be deemed to mean the General 
Services Administration Board of Contract Appeals. Appeals of 
contracting officer decisions under FAR Subpart 33.2 shall be governed 
by the Rules of the General Services Administration Board of Contract 
Appeals (48 CFR chapter 61, (part 6101)).
[50 FR 31844, Aug. 7, 1985; 51 FR 6741, Feb. 26, 1986]

[[Page 517]]



                CHAPTER 12--DEPARTMENT OF TRANSPORTATION




                          (Parts 1200 to 1299)

  --------------------------------------------------------------------
Part                                                                Page
1201            Federal Acquisition Regulation System.......         519
1202            Definitions of words and terms..............         523
1203            Improper business practices and personal 
                    conflicts of interest...................         523
1204            Administrative matters......................         525
1205            Publicizing contract actions................         526
1206            Competition requirements....................         526
1207            Acquisition planning........................         527
1209            Contractor qualifications...................         527
1210

Market research [Reserved]

1211            Describing agency needs.....................         527
1212

Acquisition of commercial items [Reserved]

1213            Small purchase and other simplified purchase 
                    procedures..............................         528
1214            Sealed bidding..............................         529
1215            Contracting by negotiation..................         530
1216            Types of contracts..........................         531
1217            Special contracting methods.................         532
1219            Small business programs.....................         533
1220            Labor surplus area contracting..............         534
1222            Application of labor laws to Government 
                    acquisitions............................         534
1223            Environment, conservation, occupational 
                    safety, and drug-free workplace.........         535
1224            Protection of privacy and freedom of 
                    information.............................         536
1225            Foreign acquisition.........................         537
1227            Patents, data, and copyrights...............         539
1228            Bonds and insurance.........................         539
1231            Contract cost principles and procedures.....         541
1232            Contract financing..........................         541
1233            Protests, disputes, and appeals.............         543
1234            Major system acquisition....................         543
1235            Research and development contracting........         543
1236            Construction and architect-engineer 
                    contracts...............................         544

[[Page 518]]

1237            Service contracting.........................         545
1242            Contract administration.....................         547
1245            Government property.........................         548
1246            Quality assurance...........................         549
1247            Transportation..............................         552
1252            Solicitation provisions and contract clauses         553
1253            Forms.......................................         573

[[Page 519]]



PART 1201--FEDERAL ACQUISITION REGULATION SYSTEM--Table of Contents




              Subpart 1201.1--Purpose, Authority, Issuance

1201.101  Purpose.
1201.103  Authority.
1201.104  Applicability.
1201.105  Issuance.
1201.105-1  Publication and code arrangement.
1201.105-2  Arrangement of regulations.
1201.105-3  Copies.
1201.106  OMB approval under the Paperwork Reduction Act.

                     Subpart 1201.2--Administration

1201.201  Maintenance of the FAR.
1201.201-1  The two councils.

             Subpart 1201.3--Agency Acquisition Regulations

1201.301  Policy.
1201.301-70  Amendment of (TAR) 48 CFR chapter 12.
1201.301-71  Effective date.
1201.301-72  TAC or TN numbering.
1201.304  Agency control and compliance procedures.

            Subpart 1201.470--Deviations From the FAR and TAR

1201.403  Individual deviations.
1201.404  Class deviations.

     Subpart 1201.6--Career Development, Contracting Authority and 
                            Responsibilities

1201.602-3  Ratification of unauthorized commitments.
1201.603-1  General.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40270, Aug. 8, 1994, unless otherwise noted.



              Subpart 1201.1--Purpose, Authority, Issuance



1201.101  Purpose.

    The Department of Transportation Acquisition Regulation (TAR) 
establishes uniform acquisition policies and procedures, which implement 
and supplement the Federal Acquisition Regulation (FAR).



1201.103  Authority.

    The Secretary of Transportation has delegated the authority to issue 
Department of Transportation (DOT) procurement regulations (i.e., the 
TAR) to the Assistant Secretary for Administration who has redelegated 
this authority to the Senior Procurement Executive (SPE).
[59 FR 40270, Aug. 8, 1994. Redesignated at 61 FR 50249, Sept. 25, 1996]



1201.104  Applicability.

    (a) Statute, the FAR, and (TAR) 48 CFR chapter 12 apply to all 
acquisitions within the Department unless otherwise excluded by statute, 
the FAR or (TAR) 48 CFR chapter 12.
    (b) The following order of precedence applies to resolve any 
acquisition regulation or procedural inconsistency found within (TAR) 48 
CFR chapter 12 or the Transportation Acquisition Manual (TAM):
    (1) Statute;
    (2) FAR or other applicable regulation;
    (3) TAR;
    (4) DOT Orders; and
    (5) TAM.
    (c) The Maritime Administration may depart from the requirements of 
the FAR and (TAR) 48 CFR chapter 12 as authorized by 40 U.S.C. 474(16), 
but shall adhere to those regulations to the maximum extent practicable. 
Exceptions from the requirements of the FAR and/or TAR shall be 
documented according to Maritime Administration procedures or in each 
contract file, as appropriate.
[59 FR 40270, Aug. 8, 1994. Redesignated at 61 FR 50249, Sept. 25, 1996]



1201.105  Issuance.



1201.105-1  Publication and code arrangement.

    (a) The TAR is published in: (1) The Federal Register; (2) cumulated 
form in the CFR; and (3) separate loose-leaf form.
    (b) The TAR is issued as chapter 12 of Title 48 of the CFR.
[59 FR 40270, Aug. 8, 1994. Redesignated at 61 FR 50249, Sept. 25, 1996]

[[Page 520]]



1201.105-2  Arrangement of regulations.

    (a) General. The TAR, which encompasses both Departmentwide and 
operating administration-unique guidance (see (TAR) 48 CFR 1201.3), 
conforms with the arrangement and numbering system prescribed by (FAR) 
48 CFR 1.104. Guidance which is unique to an operating administration 
contains the operating administration acronym directly preceding the 
cite/page number. The following acronyms apply when regulatory coverage 
is written:

FAA--Federal Aviation Administration
FHWA--Federal Highway Administration
FRA--Federal Railroad Administration
FTA--Federal Transit Administration
MARAD--Maritime Administration
NHTSA--National Highway Traffic Safety Administration
RSPA--Research and Special Programs Administration
SLSDC--Saint Lawrence Seaway Development Corporation
TASC--Transportation Administrative Service Center
USCG--United States Coast Guard

    (b) Numbering--(1) Departmentwide guidance.
    (i) The numbering illustrations at (FAR) 48 CFR 1.104-2(b) apply to 
the TAR.
    (ii) Coverage within (TAR) 48 CFR chapter 12 is identified by the 
prefix ``12'' followed by the complete FAR cite which may be down to the 
subparagraph level (e.g., (TAR) 48 CFR 1201.201-1).
    (iii) Coverage in this chapter 12 that supplements the FAR will use 
part, subpart, section and subsection numbers ending in ``70'' through 
``89''. A series of numbers beginning with ``70'' is used for provisions 
and clauses (e.g., (TAR) 48 CFR 1201.301-70).
    (iv) Coverage in (TAR) 48 CFR chapter 12, other than that identified 
with a ``70'' or higher number, that implements the FAR uses the 
identical number sequence and caption of the FAR segment being 
implemented which may be down to the subparagraph level. Subparagraph 
numbers/letters may not be shown as sequential, but may be shown by the 
specific paragraph/subparagraph implemented from the FAR (e.g., (TAR) 48 
CFR 1201.201-1 contains subparagraphs (b) and (d) because only these 
subparagraphs, correlating to FAR, are being supplemented by (TAR) 48 
CFR chapter 12).
    (2) Operating administration-unique guidance. Supplementary material 
for which there is no counterpart in the FAR or TAR shall be identified 
using chapter, part, subpart, section, or subsection numbers of ``90'' 
and up (e.g., the U.S. Coast Guard's acronym is ``USCG''; a USCG-unique 
clause pertaining to ``Inspection and/or Acceptance'' would be 
designated ``USCG 1252.246-90'').
    (c) References and citations. (TAR) 48 CFR chapter 12 may be 
referred to as the Department of Transportation Acquisition Regulation 
or the TAR. Cross references to the FAR in (TAR) 48 CFR chapter 12 will 
be cited by ``FAR'' followed by the FAR numbered cite, and cross 
reference to the TAM in (TAR) 48 CFR chapter 12 will be cited by ``TAM'' 
followed by the TAM numbered cite. References to specific cites within 
(TAR) 48 CFR chapter 12 will be by the numbered cite only.
[59 FR 40270, Aug. 8, 1994. Redesignated at 61 FR 50249, Sept. 25, 1996]



1201.105-3  Copies.

    Copies of the TAR in Federal Register, loose-leaf, and CFR form may 
be purchased from the Superintendent of Documents, Government Printing 
Office, Washington, DC, 20402.
[59 FR 40270, Aug. 8, 1994. Redesignated at 61 FR 50248, Sept. 25, 1996]



1201.106  OMB Approval Under the Paperwork Reduction Act.

    (a) Data collection by regulation. The information collection and 
recordkeeping requirements contained in (TAR) 48 CFR chapter 12 have 
been approved by the Office of Management and Budget (OMB). The OMB 
Control Number for the collection of the information under 48 CFR 
chapter 12 is 2105-0517 which expires on April 30, 1997.
    (b) Data collection under proposed contracts. Under the regulations 
implementing the requirements of the Paperwork Reduction Act (5 CFR part 
1320), OMB must approve, prior to obligation of funds, proposed 
contracts

[[Page 521]]

which require the collection of information from ten or more non-Federal 
persons or entities. Solicitations containing this type of information 
collection may be released prior to OMB approval provided:
    (1) A statement is included in the solicitation to the effect that 
contract award will not be made until OMB approval of the information 
collection requirements of the proposed contract has been obtained; and
    (2) Enough time is permitted to allow receipt of OMB approval prior 
to contract award.
[59 FR 40270, Aug. 8, 1994. Redesignated at 61 FR 50248, Sept. 25, 1996]



                     Subpart 1201.2--Administration



1201.201  Maintenance of the FAR.



1201.201-1  The two councils.

    (b) The SPE is responsible for providing a DOT representative to the 
Civilian Agency Acquisition Council.
    (d) The Office of Acquisition and Grant Management is responsible 
for Departmentwide review and coordination of cases containing proposed 
FAR revisions, as necessary, approval of DOT-generated cases, and 
submission of cases to the Civilian Agency Acquisition Council.



             Subpart 1201.3--Agency Acquisition Regulations



1201.301  Policy.

    (a) (1) Acquisition regulations--(i) Departmentwide acquisition 
regulations. The authority of the agency head under (FAR) 48 CFR 
1.301(a)(1) is delegated to the Assistant Secretary for Administration.
    (ii) Operating administration acquisition regulations. Operating 
administration acquisition regulations, and any changes thereto, shall 
be reviewed and approved by the SPE for insertion into the TAR as a TAR 
supplemental regulation before the SPE submits the proposed coverage for 
publication in the Federal Register in accordance with (FAR) 48 CFR 
1.501. Operating administration regulations may be more restrictive or 
require higher approval levels than those permitted by (TAR) 48 CFR 
chapter 12 unless specified otherwise.



1201.301-70  Amendment of (TAR) 48 CFR chapter 12.

    (a) Changes to the regulation may be the result of recommendations 
from internal DOT personnel, other Government agencies, or the public. 
These changes are to be submitted in the following format to the Office 
of Acquisition and Grant Management, 400 7th Street, S.W., Washington, 
DC 20590:
    (1) Problem: Succinctly state the problems created by current TAR 
language and describe the factual and/or legal reasons necessitating 
regulatory change.
    (2) Recommendation: Identify the recommended change by using the 
current language and lining through the words being deleted and 
inserting proposed language in brackets. If the change is extensive, 
deleted language may be displayed by forming a box with diagonal lines 
connecting the corners.
    (3) Discussion: Explain why the change is necessary and how the 
change will solve the problem. Address any cost or administrative impact 
on Government activities, offerors, and contractors. Provide any other 
helpful information and documents such as statutes, legal decisions, 
regulations, reports, etc.
    (4) Point of contact: Provide a point of contact for answering 
questions regarding the recommendation.
    (b) The TAR will be maintained by the SPE through the TAR/TAM change 
process (i.e., representatives from DOT operating administrations 
specifically designated to formulate Departmental acquisition policies 
and procedures).
    (1) Transportation Acquisition Circular (TAC). TACs containing 
loose-leaf replacement pages which revise parts, subparts, or paragraphs 
(also see (TAR) 48 CFR 1201.301-72 below) will be used to amend (TAR) 48 
CFR chapter 12. Each replacement page will bear at the top the TAC 
number and date. A vertical bar next to the coverage indicates that a 
change has been made.
    (2) TAR Notice (TN). (i) TNs shall be issued when interim guidance 
is necessary and as often as may be necessary, under any of the 
following circumstances:

[[Page 522]]

    (A) To promulgate, as rapidly as possible, selected material in a 
general or narrative manner, in advance of a TAC issuance;
    (B) To disseminate other acquisition related information; or
    (C) To issue guidance which is expected to be effective for a period 
of 1 year or less.
    (ii) Each TN will terminate upon its specified expiration date.
[59 FR 40270, Aug. 8, 1994, as amended at 62 FR 26419, May 14, 1997]



1201.301-71  Effective date.

    Unless otherwise stated, the following applies--
    (a) Statements in TACs or TNs to the effect that the material 
therein is ``effective upon receipt,'' ``upon a specified date,'' or 
that changes set forth in the document are ``to be used upon receipt,'' 
mean that any new or revised provisions, clauses, procedures, or forms 
must be included in solicitations, contracts or modifications issued 
thereafter; and
    (b) Unless expressly directed by statute or regulation, if 
solicitations are already in process or negotiations complete when the 
TAC or TN is received, the new information (e.g., forms and clauses) 
need not be included if it is determined by the chief of the contracting 
office that its inclusion would not be in the best interest of the 
Government.



1201.301-72  TAC or TN numbering.

    TACs and TNs will be numbered consecutively on a fiscal year basis 
beginning with number ``01'' prefixed by the last two digits of the 
fiscal year (e.g., TNs 94-01 and 94-02 indicate the first two TNs issued 
in fiscal year 1994).



1201.304  Agency control and compliance procedures.

    (a) DOT shall control the proliferation of acquisition regulations 
and any revisions thereto (except as noted in paragraph (b) of this 
section) by using an internal TAR change process that involves input 
from many DOT elements including operating administration 
representatives on the Procurement Management Council. The operating 
administration member shall represent their operating administration's 
viewpoint along with Departmentwide considerations in reaching a 
decision on TAR changes.
    (b) Operating administration-unique regulations will not be 
processed through the TAR Council System, but shall be reviewed by 
operating administration legal counsel and submitted to M-60 for review 
and approval. (See (TAR) 48 CFR 1252.101 for additional instructions 
pertaining to provisions and clauses.)
[59 FR 40270, Aug. 8, 1994, as amended at 62 FR 26420, May 14, 1997]



            Subpart 1201.470--Deviations From the FAR and TAR



1201.403  Individual deviations.

    The authority of the agency head under (FAR) 48 CFR 1.403 and (TAR) 
48 CFR chapter 12 is delegated to the Head of the Contracting Activity 
or designee no lower than Senior Executive Service (SES)/Flag Officer 
level. However, see Transportation Acquisition Manual (TAM) 1201.403. 
The TAM is available through the Government Printing Office.
[61 FR 50249, Sept. 25, 1996]



1201.404  Class deviations.

    Class deviations from the FAR and (TAR) 48 CFR chapter 12 may be 
granted in writing by the Senior Procurement Executive unless (FAR) 48 
CFR 1.405(e) is applicable.



     Subpart 1201.6--Career Development, Contracting Authority and 
                            Responsibilities



1201.602-3  Ratification of unauthorized commitments.

    (b) Policy. It is the policy of DOT that all procurements are to be 
made only by Government officials having authority to make such 
acquisitions. Procurements made by other than authorized personnel are 
contrary to Departmental policy and may be considered matters of serious 
misconduct on the part of the employee making an unauthorized 
commitment. Consideration will be given to initiating disciplinary 
action against an employee who makes an unauthorized commitment.

[[Page 523]]



1201.603-1  General.

    Each DOT operating administration is responsible for appointing its 
contracting officers.



PART 1202--DEFINITIONS OF WORDS AND TERMS--Table of Contents




    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



                       Subpart 1202.1--Definitions



1202.1  Definitions.

    (a) Agency, Federal agency, or Executive agency means the Department 
of Transportation.
    (b) Chief of the contracting office (COCO) means the individual(s) 
responsible for managing the contracting office(s) within an operating 
administration.
    (c) Contracting activity includes all the contracting offices within 
an operating administration and is the same as the term ``procuring 
activity.''
    (d) Contracting officer means an individual authorized by virtue of 
his/her position or by appointment to perform the functions assigned by 
the Federal Acquisition Regulation and the Transportation Acquisition 
Regulation.
    (e) Department of Transportation (DOT) means all of the operating 
administrations included within the Department of Transportation.
    (f) Head of the agency or agency head means the Deputy Secretary 
except for acquisition actions that, by the terms of a statute or 
delegation, must be done specifically by the Secretary of 
Transportation.
    (g) Head of the contracting activity (HCA) means the individual 
responsible for managing the contracting offices within an operating 
administration who is a member of the Senior Executive Service or a flag 
officer and is the same as the term ``head of the procuring activity.''
    (h) Head of the operating administration (HOA) means the individual 
appointed by the President to manage the operating administration. (For 
acquisition related matters, the Assistant Secretary for Administration 
is the HOA for the Office of the Secretary (OST)).
    (i) Operating administration (OA) means the following components of 
DOT:
    (1) Federal Aviation Administration (FAA);
    (2) Federal Highway Administration (FHWA);
    (3) Federal Railroad Administration (FRA);
    (4) Federal Transit Administration (FTA);
    (5) Maritime Administration (MARAD);
    (6) National Highway Traffic Safety Administration (NHTSA);
    (7) Transportation Administrative Service Center;
    (8) Research and Special Programs Administration (RSPA);
    (9) Saint Lawrence Seaway Development Corporation (SLSDC); and
    (10) United States Coast Guard (USCG).
    (j) Senior Procurement Executive (SPE) means the Director of the 
Office of Acquisition and Grant Management (M-60).
[59 FR 40272, Aug. 8, 1994, as amended at 61 FR 50249, Sept. 25, 1996; 
62 FR 26420, May 14, 1997]



PART 1203--IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST--Table of Contents




                       Subpart 1203.1--Safeguards

1203.101-3  Agency regulations.
1203.104-11  Processing violations or possible violations.

      Subpart 1203.2--Contractor Gratuities to Government Personnel

1203.203  Reporting suspected violations of the Gratuities clause.
1203.204  Treatment of violations.

        Subpart 1203.3--Reports of Suspected Antitrust Violations

1203.301  General.

                     Subpart 1203.4--Contingent Fees

1203.405  Misrepresentations or violations of the Covenant Against 
          Contingent Fees.

            Subpart 1203.5--Other Improper Business Practices

1203.502  Subcontractor kickbacks.

[[Page 524]]

1203.502-2  General.

Subpart 1203.8--Limitation on the Payment of Funds to Influence Federal 
                              Transactions

1203.806  Processing suspected violations.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40273, Aug. 8, 1994, unless otherwise noted.



                       Subpart 1203.1--Safeguards



1203.101-3  Agency regulations.

    (b) 5 CFR part 2635, Standards of Ethical Conduct for Employees of 
the Executive Branch, supersedes the DOT regulation at 49 CFR part 99.



1203.104-11  Processing violations or possible violations.

    (a) The COCO is the reviewing official for processing violations.
    (1) When the contracting officer receives information of a violation 
or possible violation, and concludes that the reported violation or 
possible violation of the statutory prohibitions has no impact on the 
pending procurement, the contracting officer shall forward the 
information required by (FAR) 48 CFR 3.104-11(a)(1) to the COCO for 
concurrence with the contracting officer's conclusion. If the COCO 
concurs with the conclusion, the contracting officer shall proceed with 
the award, and the COCO shall submit the information and conclusion to 
the HCA.
    (2) When the COCO does not concur with the conclusion of the 
contracting officer, the COCO shall advise the contracting officer to 
withhold award, and the COCO shall promptly forward the information and 
documentation to the HCA.
    (3) When the contracting officer determines that the information 
concerning a violation or possible violation will impact the pending 
procurement, the contracting officer shall promptly forward the 
information and documentation to the HCA.
    (b) The HCA shall review the information transmitted in accordance 
with subparagraph (a)(1) through (a)(3) of this section and take 
appropriate action, as required by (FAR) 48 CFR 3.104-11(b).
    (c) If the HCA believes that a violation has occurred and the 
information should be disclosed to a criminal investigative agency (e.g, 
the Department of Justice) or that there may be a possible violation, 
and an investigation should be conducted, the HCA shall obtain guidance 
from legal counsel and the OIG prior to taking any action. If the HCA, 
pursuant to (FAR) 48 CFR 3.104-11(f), determines that award is justified 
by urgent and compelling circumstances, or is otherwise in the interests 
of the Government, a memorandum of the facts and circumstances shall be 
signed by the HCA and placed in the contract file.



      Subpart 1203.2--Contractor Gratuities to Government Personnel



1203.203  Reporting suspected violations of the Gratuities clause.

    (a) Suspected violations of the Gratuities clause shall be reported 
to the contracting officer responsible for the acquisition (or the COCO 
if the contracting officer is suspected of the violation). The 
contracting officer (or COCO) shall obtain from the person reporting the 
violation, and any witnesses to the violation, the following 
information:
    (1) The date, time, and place of the suspected violation;
    (2) The name and title (if known) of the individual(s) involved in 
the violation; and
    (3) The details of the violation (e.g., the gratuity offered or 
intended) to obtain a contract or favorable treatment under a contract.
    (b) The person reporting the violation and witnesses (if any) should 
be requested to sign and date the information certifying that the 
information furnished is true and correct.
    (c) The COCO shall report suspected violations to the Office of the 
Inspector General (OIG) (J-1), 400 7th Street, S.W., Washington, DC, 
20590, with a copy to General Counsel (C-1) and the OA's Chief Counsel.



1203.204  Treatment of violations.

    (a) The authority of the agency head established in (FAR) 48 CFR 
3.204(a), to determine whether a gratuities clause

[[Page 525]]

violation has occurred, has been delegated to the HCA. If the decision 
maker pursuant to this delegation has been personally and substantially 
involved in the procurement, the advice of Government legal counsel 
should be sought to determine whether an alternate decision maker should 
be designated.
    (b) The COCO shall ensure that the hearing procedures required by 
FAR 3.204 are afforded to the contractor. Government legal counsel 
should be consulted regarding the appropriateness of the hearing 
procedures that are established.
    (c) If the alleged gratuities violation occurs during the ``conduct 
of an agency procurement'' as defined by (FAR) 48 CFR 3.104-4(c)(1), the 
COCO shall consult with Government legal counsel regarding the approach 
for appropriate processing of either the Procurement Integrity Act 
violation and/or the Gratuities violation.



        Subpart 1203.3--Reports of Suspected Antitrust Violations



1203.301  General.

    (b) The same procedures contained in (TAR) 48 CFR 1203.203 shall 
also be followed for suspected antitrust violations, except suspected 
antitrust violations shall be reported through legal counsel in 
accordance with (FAR) 48 CFR 3.303.



                     Subpart 1203.4--Contingent Fees



1203.405  Misrepresentations or violations of the Covenant Against Contingent Fees.

    (a) The same procedures contained in (TAR) 48 CFR 1203.203 shall 
also be followed for misrepresentation or violations of the covenant 
against contingent fees.
[59 FR 40273, Aug. 8, 1994. Redesignated at 62 FR 26420, May 14, 1997]



            Subpart 1203.5--Other Improper Business Practices



1203.502  Subcontractor kickbacks.



1203.502-2  General.

    (g) The same procedures contained in (TAR) 48 CFR 1203.203 shall 
also be followed for subcontractor kickbacks.



Subpart 1203.8--Limitation on the Payment of Funds to Influence Federal 
                              Transactions



1203.806  Processing suspected violations.

    Contracting officers shall report, in accordance with OA procedures, 
suspected violations of the requirements of 31 U.S.C. 1352 to the 
Assistant Inspector General for Investigations (JI-1), 400 Seventh 
Street, S.W., Washington, DC, 20590.



PART 1204--ADMINISTRATIVE MATTERS--Table of Contents




                   Subpart 1204.1--Contract Execution

1204.103  Contract clause.

                     Subpart 1204.8--Contract Files

1204.804  Closeout of contract files.
1204.804-1  Closeout by the office administering the contract.
1204.804-5  Detailed procedures for closing out contract files.
1204.804-570  Supporting closeout documents.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40274, Aug. 8, 1994, unless otherwise noted.



                   Subpart 1204.1--Contract Execution



1204.103  Contract clause.

    The contracting officer shall insert the clause at (FAR) 48 CFR 
52.204-1, Approval of Contract, filled in as appropriate, in 
solicitations when approval to award the resulting contract

[[Page 526]]

must be obtained from an official at a level above the contracting 
officer.



                     Subpart 1204.8--Contract Files



1204.804  Closeout of contract files.



1204.804-1  Closeout by the office administering the contract.

    (b) If the contracting officer determines appropriate, the quick 
closeout procedures under (FAR) 48 CFR 42.708 may be used for the 
settlement of indirect costs under contracts when the estimated amount 
(excluding any fixed fee) of the contract is $3 million or less.



1204.804-5  Detailed procedures for closing out contract files.



1204.804-570  Supporting closeout documents.

    (a) When applicable (see parenthetical examples in this paragraph) 
and prior to contract closure, the contracting officer shall obtain the 
listed DOT and Department of Defense (DOD) forms from the contractor to 
facilitate contract closeout.
    (1) Form DOT F 4220.4, Contractor's Release (e.g., see (FAR) 48 CFR 
52.216-7);
    (2) Form DOT F 4220.45, Contractor's Assignment of Refunds, Rebates, 
Credits and Other Amounts (e.g., see (FAR) 48 CFR 52.216-7);
    (3) Form DOT F 4220.46, Cumulative Claim and Reconciliation 
Statement (e.g., see (FAR) 48 CFR 4.804-5(a)(13); and
    (4) DD Form 882, Report of Inventions and Subcontracts (e.g., see 
(FAR) 48 CFR 52.227-14).
    (b) The forms (See (TAR) 48 CFR part 1253) are used primarily for 
the closeout of cost-reimbursement, time-and-materials, and labor-hour 
contracts. However, the forms may also be used for closeout of other 
contract types or when necessary to protect the Government's interest.



PART 1205--PUBLICIZING CONTRACT ACTIONS--Table of Contents




              Subpart 1205.1--Dissemination of Information

1205.101  Methods of disseminating information.

                 Subpart 1205.4--Release of Information

1205.402  General public.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



              Subpart 1205.1--Dissemination of Information



1205.101  Methods of disseminating information.

    (a)(2)(iii) Contracting officers shall post solicitations expected 
to exceed $25,000, if required in OA procedures.
    (b) DOT publishes a Procurement Forecast of planned procurements 
each fiscal year, which is available from the DOT Office of Small and 
Disadvantaged Business Utilization (S-40), 400 Seventh Street, S.W., 
Washington, DC, 20590.
[59 FR 40274, Aug. 8, 1994, as amended at 61 FR 50249, Sept. 25, 1996]



                 Subpart 1205.4--Release of Information



1205.402  General public.

    It is DOT policy to furnish to the general public, upon request, the 
following information on proposed contracts and contract awards:
    (a) Prior to the opening of sealed bids or the closing date for 
receipt of proposals, the names of firms invited to submit sealed bids 
or proposals;
    (b) Prior to the opening of sealed bids or the closing date for 
receipt of proposals, the names of firms which attended pre-proposal or 
pre-bid conferences, when held;
    (c) After the opening of sealed bids, names of firms which submitted 
bids; and
    (d) After contract award, the names of firms which submitted 
proposals.

Requests for other specific information shall be processed in accordance 
with the DOT Freedom of Information Act rules and regulations ((TAR) 48 
CFR 1224.202).
[59 FR 40274, Aug. 8, 1994]



PART 1206--COMPETITION REQUIREMENTS--Table of Contents




    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

[[Page 527]]



                  Subpart 1206.5--Competition Advocates



1206.501  Requirement.

    The DOT Senior Competition Advocate (SCA) is located in the Office 
of the Assistant Secretary for Administration. Correspondence may be 
sent directly to M-60.
[59 FR 40274, Aug. 8, 1994]



PART 1207--ACQUISITION PLANNING--Table of Contents




        Subpart 1207.3--Contractor Versus Government Performance

Sec.
1207.302  General.
1207.307  Appeals.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



        Subpart 1207.3--Contractor Versus Government Performance



1207.302  General.

    Procedures for DOT's implementation of OMB Circular A-76, 
Performance of Commercial Activities, and (FAR) 48 CFR 7.3 are found in 
DOT Order 4400.2 series, Performance of Commercial Activities.
[59 FR 40275, Aug. 8, 1994]



1207.307  Appeals.

    DOT appeal procedures for informal administrative review of initial 
cost-comparison results are contained in DOT Order 4400.2 series.
[59 FR 40275, Aug. 8, 1994]



PART 1209--CONTRACTOR QUALIFICATIONS--Table of Contents




Sec.

          Subpart 1209.5--Organizational Conflicts of Interest

1209.507  Solicitation provisions.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40275, Aug. 8, 1994, unless otherwise noted.



          Subpart 1209.5--Organizational Conflicts of Interest



1209.507  Solicitation provisions.

    The contracting officer may insert the provision at (TAR) 48 CFR 
1252.209-70, ``Disclosure of Conflicts of Interest'' in all 
solicitations for negotiated acquisitions, when simplified acquisitions 
procedures in (FAR) 48 CFR Part 13, are not used and when the 
contracting officer believes the conditions enumerated in (FAR) 48 CFR 
9.507-2 warrant inclusion.
[61 FR 50249, Sept. 25, 1996]



PART 1210--MARKET RESEARCH [RESERVED]






PART 1211--DESCRIBING AGENCY NEEDS--Table of Contents




Sec.

     Subpart 1211.1--Selecting and Developing Requirements Documents

1211.104  Items peculiar to one manufacturer.
1211.104-70  Offer evaluation and award, brand name or equal 
          descriptions.

      Subpart 1211.2--Using and Maintaining Requirements Documents

1211.204-70  Solicitation provisions and contract clauses.

               Subpart 1211.6--Priorities and Allocations

1211.602  General.
1211.204-90  Solicitation provision and contract clause (USCG).

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  61 FR 50249, Sept. 25, 1996, unless otherwise noted.



     Subpart 1211.1--Selecting and Developing Requirements Documents

    Source: 62 FR 26420, May 14, 1997, unless otherwise noted.

[[Page 528]]



1211.104  Items peculiar to one manufacturer.



1211.104-70  Offer evaluation and award, brand name or equal descriptions.

    (a) An offer may not be rejected for failure of the offered product 
to equal a characteristic of a brand name product if it was not 
specified in the brand name or equal description. However, if it is 
clearly established that the unspecified characteristic is essential to 
the intended end use, the solicitation may be defective and need to be 
amended or the requirement resolicited.
    (b) The contracting officer shall insert in the solicitation an 
entry substantially as follows for completion by the offeror in the item 
listing after each item or component part of an end item to which a 
brand name or equal purchase description applies:

Offering on:

 _______________________________________________________________________
Manufacturer's Name:

 _______________________________________________________________________
Brand:

 _______________________________________________________________________
No:

 _______________________________________________________________________

    (c) Except when bid samples are requested for brand name or equal 
procurements, the following note shall be inserted in the item listing 
after each brand name or equal item (or component part), or at the 
bottom of each page, listing several such items, or in a manner that may 
otherwise direct the offeror's attention to this note:

    Offerors offering other than brand name items identified herein 
should furnish with their offers adequate information to ensure that a 
determination can be made as to the equality of the product(s) offered 
(see the provision at (TAR) 48 CFR 1252.211-70, Brand Name or Equal).



      Subpart 1211.2--Using and Maintaining Requirements Documents



1211.204-70  Solicitation provisions and contract clauses.

    (a) The contracting officer shall insert the provision at (TAR) 48 
CFR 1252.211-70, Brand Name or Equal, in solicitations using a brand 
name or equal purchase description whenever practicable.
    (b) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.211.71, Index for Specifications, when an index or table of 
contents may be furnished with the specification.
[62 FR 26420, May 14, 1997]



               Subpart 1211.6--Priorities and Allocations



1211.602  General.

    (c) The USCG is the only DOT OA delegated authority under the 
Defense Priorities and Allocations System (DPAS) regulation (15 CFR 700) 
to assign priority ratings on contracts and orders placed with 
contractors to acquire products, materials, and services in support of 
USCG certified national defense related programs.



1211.204-90  Solicitation provision and contract clause (USCG).

    (a) The contracting officer shall insert the USCG clause at (TAR) 48 
CFR 1252.211-90, Bar Coding Requirement (also see (TAR) 48 CFR 1213.507-
90(a)) when the bar coding of supplies is necessary for the USCG.
    (b) See (TAR) 48 CFR 1213.507-90 for a provision which is required 
when the USCG clause at (TAR) 48 CFR 1252.211-90, Bar Coding 
Requirement, is used with simplified acquisition procedures.



PART 1212--ACQUISITION OF COMMERCIAL ITEMS [RESERVED]






PART 1213--SMALL PURCHASE AND OTHER SIMPLIFIED PURCHASE PROCEDURES--Table of Contents




                         Subpart 1213.1--General

1213.107-90  Solicitation provision (supplies). (USCG)

                     Subpart 1213.5--Purchase Orders

1213.507-90  Clauses. (USCG)

 Subpart 1213.71--Department of Transportation Procedures for Acquiring 
                            Training Services

1213.7100  Applicability.

[[Page 529]]

1213.7101  Solicitation provision and contract clause.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



                         Subpart 1213.1--General



1213.107-90  Solicitation provision (supplies). (USCG)

    The contracting officer shall insert the USCG provision at (TAR) 48 
CFR 1252.213-90, Evaluation Factor for Coast Guard Performance of Bar 
Coding Requirement, in requests for quotations when the USCG clause at 
(TAR) 48 CFR 1252.211-90, Bar Coding Requirement, is used with 
simplified acquisition procedures.
[59 FR 40276, Aug. 8, 1994, as amended at 61 FR 50249, Sept. 25, 1996]



                     Subpart 1213.5--Purchase Orders



1213.507-90  Clauses. (USCG)

    The contracting officer shall insert the USCG clause at (TAR) 48 CFR 
1252.211-90, Bar Coding Requirement, in requests for quotations and 
purchase orders issued by the Inventory Control Points when bar coding 
of supplies is necessary.
[59 FR 40276, Aug. 8, 1994, as amended at 61 FR 50249, Sept. 25, 1996]



 Subpart 1213.71--Department of Transportation Procedures for Acquiring 
                            Training Services

    Source:  61 FR 391, Jan. 5, 1996, unless otherwise noted.



1213.7100  Applicability.

    (a) DOT policy at (TAR) 48 CFR 1237.7000 also applies to the 
Standard Form (SF) 182, Request, Authorization, Agreement and 
Certification of Training, which may be used to acquire training 
services; however, the policy does not apply to training services 
acquired by the Government purchase/credit card. The Government 
purchase/credit card can only be used to acquire training services 
valued at $2,500 or less.
    (b) As reflected in (TAR) 48 CFR 1237.7002, this policy does not 
apply to training attended by DOT employees which is scheduled and 
conducted by Government sources of supply, educational institutions, or 
private entities where DOT does not control or sponsor the training. 
Examples of when the policy does and does not apply include:
    (1) When SF 182s are issued for three DOT employees to attend a one 
week course at a university or other private entity, the policy does not 
apply. DOT does not control this course because the university or 
private entity has a contract in place with the training provider and 
DOT is placing an order under an existing contract; and
    (2) When DOT awards a contract to a university or other private 
entity to provide training for DOT and/or other Government personnel, 
the policy applies. DOT controls this course; therefore, no soliciting 
or advertising of private, non-Government training while conducting the 
contracted-for training is permitted.



1213.7101  Solicitation provision and contract clause.

    (a) Contracting officers shall insert the provision at (TAR) 48 CFR 
1252.237-71, Certification of Data, in all solicitations and requests 
for quotations, and the clause at (TAR) 48 CFR 1252.237-72, Prohibition 
on Advertising, in solicitations, requests for quotations, and all 
contracts (e.g., purchase orders, SF 182s) for training services when 
the content and/or presentation of the training is controlled by DOT.
    (b) Contracting officers shall incorporate the successful offeror's 
certified data into any resultant contract(s). Certified data may be 
incorporated by reference, if the contracting officer determines it 
contains sufficient descriptive information (i.e., dated material such 
as resumes, company and/or personnel qualifications) to reliably 
describe the certified data submitted.



PART 1214--SEALED BIDDING--Table of Contents




                  Subpart 1214.2--Solicitation of Bids

1214.205  Solicitation mailing lists.
1214.205-1  Establishment of lists.

                   Subpart 1214.3--Submission of Bids

1214.302  Bid submission.

[[Page 530]]

1214.303  Modification or withdrawal of bids.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40276, Aug. 8, 1994, unless otherwise noted.



                  Subpart 1214.2--Solicitation of Bids



1214.205  Solicitation mailing lists.



1214.205-1  Establishment of lists.

    (b) The issuance of a solicitation within a reasonable time (i.e., 
normally 45 days) after receipt of a SF 129, Solicitation Mailing List 
Application, constitutes the notification required under (FAR) 48 CFR 
14.205-1. If a solicitation is not anticipated for release within a 
reasonable time after receipt of the SF 129 or if an applicant does not 
meet the criteria for placement on the list, the contracting officer 
shall provide a written notification of acceptance or non-acceptance to 
the applicant within 45 days of application receipt.
    (d) Requests for supplemental information shall normally be attached 
to the SF 129 and forwarded to potential suppliers for completion.



                   Subpart 1214.3--Submission of Bids



1214.302  Bid submission.

    (b) Contracting officers may permit telegraphic bids to be 
communicated by means of a telephone call from the telegraph office to 
the designated office provided that procedures and controls have been 
established by the COCO for receiving and safeguarding these incoming 
bids.



1214.303  Modification or withdrawal of bids.

    (b) The receipt required by (FAR) 48 CFR 14.303(b) for withdrawal of 
a bid in person shall be worded substantially as follows:

    I, as a bona fide agent for or representative of

 _______________________________________________________________________
(Bidder's name and address), am authorized to withdraw the bid on IFB 
No. ________ scheduled for opening on ________________ and hereby 
acknowledge receipt of the unopened bid.

 _______________________________________________________________________
(Name and telephone No.)

 _______________________________________________________________________
(Date)
[59 FR 40276, Aug. 8, 1994, as amended at 62 FR 26420, May 14, 1997]



PART 1215--CONTRACTING BY NEGOTIATION--Table of Contents




          Subpart 1215.1--General Requirements for Negotiation

1215.106  Contract clauses.

  Subpart 1215.4--Solicitation and Receipt of Proposals and Quotations

1215.413  Disclosure and use of information before award.
1215.413-1  Alternate I.
1215.413-2  Alternate II.

                    Subpart 1215.6--Source Selection

1215.612  Formal source selection.

                    Subpart 1215.8--Price Negotiation

1215.804-6  Instructions for submission of cost or pricing data or 
          information other than cost or pricing data.

                         Subpart 1215.9--Profit

1215.970  Payment of profit or fee under contracts.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40276, Aug. 8, 1994, unless otherwise noted.



          Subpart 1215.1--General Requirements for Negotiation



1215.106  Contract clauses.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.215-70, Key Personnel and/or Facilities, in solicitations and 
contracts when the selection for award is substantially based on the 
offeror's possession of special capabilities regarding personnel and/or 
facilities.

[[Page 531]]



  Subpart 1215.4--Solicitation and Receipt of Proposals and Quotations



1215.413  Disclosure and use of information before award.



1215.413-1  Alternate I.

    The alternate procedures at (FAR) 48 CFR 15.413-2 shall be used in 
lieu of the alternate procedures prescribed at (FAR) 48 CFR 15.413-1.



1215.413-2  Alternate II.

    (e) The notice at (FAR) 48 CFR 15.413-2(e) shall be placed on the 
cover sheet of all proposals, whether solicited or unsolicited. The 
cite(s) under the first paragraph of the notice shall include, as a 
minimum, (TAR) 48 CFR 1215.413-2(f) and the cite of any OA implementing 
procedures.
    (f) Proposals may be released outside of the Government if it is 
necessary to receive competent technical and/or management evaluation as 
long as the requirements of (FAR) 48 CFR 15.413-2(f) are met.
[59 FR 40276, Aug. 8, 1994, as amended at 60 FR 55802, Nov. 3, 1995]



                    Subpart 1215.6--Source Selection



1215.612  Formal source selection.

    DOT's formal source selection procedures are contained in TAM 
(Transportation Acquisition Manual which is stocked by the Government 
Printing Office), Chapter 1215, Appendix A.



                    Subpart 1215.8--Price Negotiation



1215.804-6  Instructions for submission of cost or pricing data or information other than cost or pricing data.

    The contracting officer may require the submission of DOT Form 
4220.44, Contract Pricing Summary, when submitting a proposal that 
requires a SF 1411.
[59 FR 40276, Aug. 8, 1994, as amended at 61 FR 50249, Sept. 25, 1996]



                         Subpart 1215.9--Profit



1215.970  Payment of profit or fee under contracts.

    Profit or fee shall only be paid on definitized contracts and 
modifications. Any profit or fee earned during the undefinitized period 
shall be paid once the contract and/or modification, as applicable, is 
definitized.



PART 1216--TYPES OF CONTRACTS--Table of Contents




                  Subpart 1216.2--Fixed-Price Contracts

1216.203  Fixed-price contracts with economic price adjustment.
1216.203-4  Contract clauses.
1216.203-470  Solicitation provision.

                   Subpart 1216.4--Incentive Contracts

1216.405  Contract clauses.

              Subpart 1216.5--Indefinite-Delivery Contracts

1216.505  Ordering.

  Subpart 1216.6--Time-and-Materials, Labor-Hour, and Letter Contracts

1216.603  Letter contracts.
1216.603-4  Contract clauses.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40277, Aug. 8, 1994, unless otherwise noted.



                  Subpart 1216.2--Fixed-Price Contracts



1216.203  Fixed-price contracts with economic price adjustment.



1216.203-4  Contract clauses.



1216.203-470  Solicitation provision.

    The contracting officer shall insert the provision at (TAR) 48 CFR 
1252.216-70, Evaluation of Offers Subject to an Economic Price 
Adjustment Clause, in solicitations containing an economic price 
adjustment clause.



                   Subpart 1216.4--Incentive Contracts



1216.405  Contract clauses.

    (a) The contracting officer shall insert the clause at (TAR) 48 CFR

[[Page 532]]

1252.216-71, Determination of Award Fee, in all cost-plus-award-fee 
solicitations and contracts.
    (b) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.216-72, Performance Evaluation Plan, in all cost-plus-award-fee 
solicitations and contracts.
    (c) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.216-73, Distribution of Award Fee, in all cost-plus-award-fee 
solicitations and contracts.



              Subpart 1216.5--Indefinite-Delivery Contracts



1216.505  Ordering.

    (b)(4) Unless otherwise provided in OA procedures, the OA 
Competition Advocate is designated as the OA Task and Delivery Order 
Ombudsman.
    (i) If any corrective action is needed after reviewing complaints 
from contractors on task and delivery order contracts, the OA Ombudsman 
shall provide a written determination of such action to the contracting 
officer.
    (ii) Issues that cannot be resolved within the OA, are to be 
forwarded to the DOT Task and Delivery Order Ombudsman for review and 
resolution.
[61 FR 50249, Sept. 25, 1996]



  Subpart 1216.6--Time-and-Materials, Labor-Hour, and Letter Contracts



1216.603  Letter contracts.



1216.603-4  Contract clause.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.216-74, Settlement of Letter Contract, in all definitized letter 
contracts.



PART 1217--SPECIAL CONTRACTING METHODS--Table of Contents




                  Subpart 1217.1--Multiyear Contracting

1217.102  Policy.
1217.102-1  Uses.

Subpart 1217.70--Fixed Price Contracts for Vessel Repair, Alteration or 
                               Conversion

1217.7000  Clauses.

          Subpart 1217.71--Energy Savings Performance Contracts

1217.7100  Policy.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40277, Aug. 8, 1994, unless otherwise noted.



                  Subpart 1217.1--Multiyear Contracting



1217.102  Policy.



1217.102-1  Uses.

    The FAA Administrator has been granted specific statutory multiyear 
contracting authority by the Aviation Safety and Capacity Expansion Act 
of 1990 (Subtitle B of Title IX of Pub. L. 101-508, Omnibus Budget 
Reconciliation Act of 1990, Section 9118). FAA implementing procedures 
are contained in Federal Aviation Acquisition Manual Subchapter 1217.1.



Subpart 1217.70--Fixed Price Contracts for Vessel Repair, Alteration or 
                               Conversion



1217.7000  Clauses.

    The following clauses are to be used in specific solicitations and 
contracts:
    (a) The clauses set forth in (TAR) 48 CFR 1252.217-71 through (TAR) 
48 CFR 1252.217-74 and (TAR) 48 CFR 1252.217-76 through (TAR) 48 CFR 
1252.217-80 shall be included and clause (TAR) 48 CFR 1252.217-75 may be 
included in sealed bid fixed-price solicitations and contracts for 
vessel repair, alteration, or conversion which are to be performed 
within the United States, its possessions, or Puerto Rico.
    (b) Unless inappropriate, the clauses set forth in (TAR) 48 CFR 
1252.217-71 through (TAR) 48 CFR 1252.217-74 and (TAR) 48 CFR 1252.217-
76 through (TAR) 48 CFR 1252.217-80 should be included and (TAR) 48 CFR 
1252.217-75 may be included in negotiated solicitations and contracts to 
be performed outside the United States.
    (c) The clause at (TAR) 48 CFR 1252.217-81, Guarantee, shall be used 
where general guarantee provisions are deemed desirable by the 
contracting officer.

[[Page 533]]

    (1) When inspection and acceptance tests will afford full protection 
to the Government in ascertaining conformance to specifications and the 
absence of defects and deficiencies, no guarantee clause for that 
purpose shall be included in the contract.
    (2) The customary guarantee period, to be inserted in the first 
sentence of the clause at (TAR) 48 CFR 1252.217-81, Guarantee, is 60 
days. However, in certain instances, the contracting officer may desire 
to include a clause in a contract for a guarantee period of more than 60 
days. In such instances:
    (i) Where, after full inquiry, it has been determined that such 
longer guarantee period will not involve increased costs, a longer 
guarantee period may be substituted by the contracting officer for the 
usual 60 days; or
    (ii) Where the full inquiry discloses that such longer guarantee 
period will involve, or is reasonably expected to involve, increased 
costs, such facts and the reasons for the need for such longer period 
shall be set forth in letter form to the COCO, requesting approval for 
use of guarantee period in excess of 60 days. Upon approval, the longer 
period may be inserted by the contracting officer in the first sentence 
of the clause at (TAR) 48 CFR 1252.217-81, Guarantee.



          Subpart 1217.71--Energy Savings Performance Contracts



1217.7100  Policy.

    Federal agencies may enter into multi-year contracts for a period of 
up to 25 years under Title VIII of the National Energy Conservation 
Policy Act, 42 U.S.C. 8287, as amended. Energy savings performance 
arrangements are appropriate where a contractor makes improvements and/
or operating changes to Federally-owned buildings and facilities to 
improve energy efficiency, at no cost to the Federal Government in 
exchange for a share of energy savings directly resulting from the 
changes. Proposed actions under this section shall be coordinated with 
M-60.



PART 1219--SMALL BUSINESS PROGRAMS--Table of Contents




                        Subpart 1219.2--Policies

1219.201  General policy.

Subpart 1219.7--Subcontracting With Small Business, Small Disadvantaged 
            Business and Women-Owned Small Business Concerns

1219.708  Solicitation provisions and contract clauses.
1219.708-70  DOT solicitation and contract clause.

  Subpart 1219.10--Small Business Competitiveness Demonstration Program

1219.1005  Applicability.
1219.1006  Procedures.

Appendix A to Subpart 1219.10

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40278, Aug. 8, 1994, unless otherwise noted.



                        Subpart 1219.2--Policies



1219.201  General policy.

    (c) The Director, Office of Small and Disadvantaged Business 
Utilization (S-40), is responsible for the implementation and execution 
of the small and small disadvantaged business programs required by 
sections 8 and 15 of the Small Business Act.
[59 FR 40278, Aug. 8, 1994, as amended at 61 FR 50249, Sept. 25, 1996]



Subpart 1219.7--Subcontracting With Small Business, Small Disadvantaged 
            Business and Women-Owned Small Business Concerns



1219.708  Solicitation provisions and contract clauses.



1219.708-70  DOT solicitation and contract clause.

    The contracting officer shall insert the clause at 1252.219-70, 
Small Business and Small Disadvantaged Business

[[Page 534]]

Subcontracting Reporting, in solicitations and contracts containing the 
clause at (FAR) 48 CFR 52.219-9.



  Subpart 1219.10--Small Business Competitiveness Demonstration Program



1219.1005  Applicability.

    (b) Targeted industry categories. DOT's targeted industry categories 
are shown in appendix A.



1219.1006  Procedures.

    (c) Emerging small business set-aside. The Office of Federal 
Procurement Policy published a notice in the Federal Register, dated 
September 13, 1991, that increased the emerging small business reserve 
amount for Architect-Engineer (A-E) services from $25,000 to $50,000. 
Therefore, A-E services below $50,000 are reserved for emerging small 
businesses, if the conditions of (FAR) 48 CFR 19.1006(c)(1) are met.

                      Appendix A to Subpart 1219.10                     
------------------------------------------------------------------------
                                              FPDS product and service  
     Targeted industry categories \1\                   code            
------------------------------------------------------------------------
(1) Engineering Development...............  AT94                        
(2) Systems Engineering Services (Only)...  R414                        
(3) Radio/TV Communication Equipment        5820                        
 (except airborne).                                                     
(4) Maintenance, Repair, and Rebuilding of  J028/J010                   
 engines, turbines, components and weapons                              
 equipment.                                                             
(5) ADP Central Processing Units:                                       
  Analog..................................  7020                        
  Digital.................................  7021                        
  Hybrid..................................  7022                        
(6) ADP Support Equipment.................  7035                        
(7) ADP Components........................  7050                        
(8) ADP Development Services and ADP        D302/D305                   
 Teleprocessing and Timesharing Services.                               
(9) Gas Turbines and Jet Engines,           2840                        
 Aircraft; and Components.                                              
(10) Radar Equipment (except airborne) and  5840/AT31                   
 Navigation and Navigational Aids (basic                                
 research).                                                             
------------------------------------------------------------------------
\1\ The industry categories were derived from Federal Procurement Data  
  System Product and Service Codes Manual.                              

[59 FR 40278, Aug. 8, 1994. Redesignated and amended at 61 FR 50250, 
Sept. 25, 1996]



PART 1220--LABOR SURPLUS AREA CONTRACTING--Table of Contents




                       Subpart 1220.90--Local Hire

1220.9000  Policy. (USCG)
1220.9001  Solicitation provision and contract clause. (USCG)

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



                       Subpart 1220.90--Local Hire



1220.9000  Policy. (USCG)

    Pub. L. 101-225, Coast Guard Authorization Act of 1989, Section 206, 
added Section 666 to Title 14 of the United States Code, which requires 
the U.S. Coast Guard to include a provision for local hire in each 
contract for construction or services to be performed in whole or in 
part in a State that has an unemployment rate in excess of the national 
average rate of unemployment (as determined by the Secretary of Labor). 
The Secretary of Transportation may waive this requirement in the 
interest of national security or economic efficiency.
[59 FR 40278, Aug. 8, 1994]



1220.9001  Solicitation provision and contract clause. (USCG)

    The contracting officer shall insert the USCG clause at (TAR) 48 CFR 
1252.220-90, Local Hire Provision, in all solicitations and contracts as 
required by (TAR) 48 CFR 1220.9000.
[59 FR 40278, Aug. 8, 1994]



PART 1222--APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITIONS--Table of Contents




                  Subpart 1222.1--Basic Labor Policies

1222.101  Labor relations.
1222.101-70  Admittance of union representatives to DOT installations.
1222.101-71  Contract clauses.

  Subpart 1222.4--Labor Standards for Contracts Involving Construction

1222.406  Administration and enforcement.
1222.406-9  Withholding from or suspension of contract payments.

            Subpart 1222.6--Walsh-Healey Public Contracts Act

1222.608  Procedures.
1222.608-4  Award pending final determination.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

[[Page 535]]


    Source:  59 FR 40279, Aug. 8, 1994, unless otherwise noted.



                  Subpart 1222.1--Basic Labor Policies



1222.101  Labor relations.



1222.101-70  Admittance of union representatives to DOT installations.

    (a) It is the policy of DOT to admit labor union representatives of 
contractor employees to DOT installations to visit work sites and 
transact labor union business with contractors, their employees, or 
union stewards pursuant to existing union collective bargaining 
agreements. Their presence shall not interfere with the contractor's 
work progress under a DOT contract nor violate the safety or security 
regulations that may be applicable to persons visiting the installation. 
The union representatives will not be permitted to conduct meetings, 
collect union dues, or make speeches concerning union matters while 
visiting a work site.
    (b) Whenever a union representative is denied entry to a work site, 
the person denying entry shall make a written report to the DOT labor 
coordinator (i.e., Director, Office of Economics (P-35), Office of the 
Secretary) or OA labor advisor, if any, within two working days after 
the request for entry is denied. The report shall include the reason(s) 
for the denial, the name of the representative denied entry, the union 
affiliation and number, and the name and title of the person that denied 
the entry.



1222.101-71  Contract clauses.

    (a) The contracting officer, may, when applicable, insert the clause 
at (TAR) 48 CFR 1252.222-70, Strikes or Picketing Affecting Timely 
Completion of the Contract Work, in solicitations and contracts.
    (b) The contracting officer may, when applicable, insert the clause 
at (TAR) 48 CFR 1252.222-71, Strikes or Picketing Affecting Access to a 
DOT Facility, in solicitations and contracts.



  Subpart 1222.4--Labor Standards for Contracts Involving Construction



1222.406  Administration and enforcement.



1222.406-9  Withholding from or suspension of contract payments.

    (c) Disposition of contract payments withheld or suspended. (1) 
Forwarding wage underpayments to the Comptroller General. The 
contracting officer shall ensure that a completed Form DOT F 4220.7, 
Employee Claim for Wage Restitution, is obtained from each employee 
claiming restitution under the contract. The Comptroller General (Claims 
Division) must receive this form with a completed SF 1093, Schedule of 
Withholding Under the Davis-Bacon Act and/or the Contract Work Hours and 
Safety Standards Act, before payment can be made to the employee.



            Subpart 1222.6--Walsh-Healey Public Contracts Act



1222.608  Procedures.



1222.608-4  Award pending final determination.

    (b) The official authorized to approve the contracting officer's 
written certification required by (FAR) 48 CFR 22.608-4(b)(1) is the 
HCA.



PART 1223--ENVIRONMENT, CONSERVATION, OCCUPATIONAL SAFETY, AND DRUG-FREE WORKPLACE--Table of Contents




 Subpart 1223.3--Hazardous Material Identification and Material Safety 
                                  Data

1223.303  Contract clause.

     Subpart 1223.70--Safety Requirements for Selected DOT Contracts

1223.7000  Contract clauses.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

[[Page 536]]



 Subpart 1223.3--Hazardous Material Identification and Material Safety 
                                  Data



1223.303  Contract clause.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.223-70, Removal or Disposal of Hazardous Substances--Applicable 
Licenses and Permits, in solicitations and contracts involving the 
removal or disposal of hazardous waste material.
[59 FR 40279, Aug. 8, 1994]



     Subpart 1223.70--Safety Requirements for Selected DOT Contracts



1223.7000  Contract clauses.

    (a) Where all or part of a contract will be performed on Government-
owned or leased property, the contracting officer shall insert the 
clause at (TAR) 48 CFR 1252.223-71, Accident and Fire Reporting.
    (b) For all solicitations and contracts under which human test 
subjects will be utilized, the contracting officer shall insert the 
clause at (TAR) 48 CFR 1252.223-72, Protection of Human Subjects. Copies 
of NHTSA Orders 700-1, 700-3 and 700-4 may be obtained in writing from 
NHTSA, Office of Administrative Operations, Distribution Services, NAD-
51, 400 Seventh Street SW., Washington, DC 20590.
[59 FR 40279, Aug. 8, 1994]



PART 1224--PROTECTION OF PRIVACY AND FREEDOM OF INFORMATION--Table of Contents




            Subpart 1224.1--Protection of Individual Privacy

1224.102-70  Applicability.
1224.103  Procedures.

               Subpart 1224.2--Freedom of Information Act

1224.202  Policy.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40279, Aug. 8, 1994, unless otherwise noted.



            Subpart 1224.1--Protection of Individual Privacy



1224.102-70  Applicability.

    (a) Illustrations of systems of records to which the Privacy Act 
applies and which shall not be released irrespective of whether the 
Government or a contractor acting on behalf of the Government is 
maintaining the records include the following:
    (1) Personnel, payroll and background records personal to any 
officer or employee of DOT, or other person, including his or her 
residential address;
    (2) Medical histories and medical records concerning individuals, 
including applicants for licenses; and
    (3) Any other detailed record containing information identifiable 
with a particular person.
    (b) Illustrations of systems of records to which the Privacy Act 
does not apply include:
    (1) Records that are maintained by a contractor on individuals 
employed by the contractor in the process of providing goods and 
services to the Federal government; and
    (2) The records generated, when contracting with an educational 
institution, on contract students pursuant to their attendance (e.g., 
admission forms, grade reports), provided that they are similar to those 
maintained under contracts with educational institutions to provide 
training, generated on students working under the contract relative to 
their attendance (e.g., admission forms, grade reports), similar to 
those maintained on other students and are commingled with records of 
other students.



1224.103  Procedures.

    DOT's rules and regulations implementing the Privacy Act of 1974 are 
located at 49 CFR part 10.
[61 FR 50250, Sept. 25, 1996]



               Subpart 1224.2--Freedom of Information Act



1224.202  Policy.

    DOT rules and regulations implementing the Freedom of Information 
Act (FOIA) and the names and addresses of the OA FOIA offices are 
located in

[[Page 537]]

49 CFR part 7. Specific contract award information shall be requested 
from the FOIA office of the OA making the contract award.



PART 1225--FOREIGN ACQUISITION--Table of Contents




   Subpart 1225.90--But American Act--Steel and Manufactured Products

1225.9000  Scope. (FAA)
1225.9001  Definitions. (FAA)
1225.9002  Policy. (FAA)
1225.9003  Order of precedence. (FAA)
1225.9004  Findings. (FAA)
1225.9005  Solicitation provisions and contract clauses. (FAA)

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40280, Aug. 8, 1994, unless otherwise noted.



   Subpart 1225.90--Buy American Act--Steel and Manufactured Products



1225.90  Steel and manufactured products.



1225.9000  Scope. (FAA)

    For the FAA, this subpart implements the Buy American provisions of 
the Aviation Safety and Capacity Expansion Act of 1990 (Subtitle B of 
Title IX of Pub. L. 101-508, the Omnibus Budget Reconciliation Act of 
1990), and Pub. L. 102-581, The Airport and Airway Safety, Capacity, 
Noise Improvement, and Intermodal Transportation Act of 1992, Title I, 
Sec. 103 and 104, as these apply to the obligation of funds made 
available in appropriations after November 5, 1990.



1225.9001  Definitions. (FAA)

    As used in this subpart:
    Manufactured product means an item produced as a result of the 
manufacturing process.
    Manufacturing process means the application of processes to alter 
the form or function of materials or of elements of the product in a 
manner adding value and transforming those materials or elements so that 
they represent a new end product functionally different from that which 
would result from mere assembly of the elements or materials.



1225.9002  Policy. (FAA)

    (a) This subpart sets forth the policy for the FAA pursuant to Pub. 
L. 101-508, and notwithstanding any other provision of law, the 
Secretary of Transportation shall not obligate any funds authorized to 
be appropriated for any project unless steel and manufactured products 
used in such projects are produced in the United States. Projects funded 
by the Research, Engineering and Development appropriation are excluded 
from this provision.
    (b) The Act provides that the general provisions in paragraph (a) 
shall not apply where the Secretary of Transportation finds:
    (1) That their application would be inconsistent with the public 
interest;
    (2) That such materials and products are not produced in the United 
States in sufficient and reasonably available quantities and of a 
satisfactory quality;
    (3) In the case of the procurement of facilities and equipment under 
the Airport and Airway Improvement Act of 1982,
    (i) The cost of components and subcomponents which are produced in 
the United States is more than 60 percent of the cost of all components 
of the facility or equipment used in the project, and
    (ii) Final assembly of the facility or equipment described in this 
paragraph has taken place in the United States; or
    (4) Inclusion of domestic material will increase the cost of the 
overall project contract by more than 25 percent.
    (c) There is no restriction against a company offering foreign steel 
or manufactured products in its bid or proposal. The FAA, however, may 
not award to that company unless it is pursuant to one of the exceptions 
listed under (TAR) 48 CFR 1225.9002(b) (FAA).
    (d) For the purpose of this subpart, in calculating components' 
costs, labor costs involved in final assembly shall not be included in 
the calculation.

[[Page 538]]



1225.9003  Order of precedence. (FAA)

    (a) Any acquisition of the FAA not subject to Pub. L. 101-508 should 
be treated as covered under the Buy American Act, unless a Buy American 
Act exception applies.
    (b) Nothing in this subpart relieves the contracting officer of 
responsibility for complying with the Federal Acquisition Regulation 
(FAR) 48 CFR subpart 25.1, Buy American Act--Supplies, and (FAR) 48 CFR 
subpart 25.2, Buy American Act Construction Materials, including the 
requirement to insert any FAR required Buy American clause or provision 
in solicitations or contracts. To the extent that there may be a 
conflict between the requirements of the clause prescribed by this 
subpart and a FAR prescribed Buy American clause, both of which may be 
required to be included in the same contract, this subpart's clause 
takes precedence.
    (c) The certificate required to be executed by this subpart, 
entitled, ``Buy American Certificate--Steel and Manufactured Products'' 
((TAR) 48 CFR 1252.225-90), will be in addition to any Buy American 
certification required by the FAR. Although this may appear to be a 
situation of a clear duplication of certifications (two Buy American 
certificates in the same acquisition) the separate certificates 
implement two separate statutes, which differ in coverage. Consequently, 
the contents of the two certificates included in the same acquisition 
may differ. As one example: such materials as copper or aluminum, if end 
products in the contract and if nondomestic, would be listed in the FAR 
Buy American certificate, whereas they would not be listed in the 
certificate required by this subpart. This is because only steel, among 
nonmanufactured materials, is subject to the restrictions of Pub. L. 
101-508, whereas all nondomestic end products are subject to 
restrictions of the Buy American Act (unless a Buy American Act 
exception applies).



1225.9004  Findings. (FAA)

    In respect to the four findings enumerated in (TAR) 48 CFR 
1225.9002(b) (FAA), the following applies:
    (a) Based on delegations from the Secretary and the Federal Aviation 
Administrator, authorities for the making of these findings are 
established as follows:
    (1) Contracts exceeding $1,000,000: Head of the Contracting 
Activity. For construction contracts, this is for an amount exceeding 
$100,000.
    (2) Contracts below the above dollar thresholds: Contracting 
officer.
    (b) All findings, except those authorized to be made by the 
contracting officer, shall be coordinated with the Director, Office of 
Acquisition Policy and Oversight, ACQ-1. Every finding shall be 
coordinated with the Office of Chief Counsel and the appropriate Program 
Office.



1225.9005  Solicitation provisions and contract clauses. (FAA)

    (a) If the procurement includes the acquisition of steel or 
manufactured products, the contracting officer shall insert the FAA 
provision at (TAR) 48 CFR 1252.225-90, Buy American Certificate--Steel 
and Manufactured Products (July 1992), in solicitations. Projects funded 
by the Research, Engineering and Development appropriation to carry out 
the purpose of Section 302 of the Federal Aviation Act of 1958, as 
amended (49 U.S.C. App. 1353) are excluded from this requirement. Only 
those contract actions obligating funds made available in appropriations 
after November 5, 1990, that have been authorized pursuant to 49 U.S.C. 
106(k) and 506(a) of the Airport and Airway Improvement Act of 1982, are 
subject to this requirement.
    (b) If the procurement includes the acquisition of steel or 
manufactured products, the contracting officer shall insert the FAA 
clause at (TAR) 48 CFR 1252.225-91, Buy American--Steel and Manufactured 
Products (July 1992) in solicitations and contracts. Projects funded by 
the Research, Engineering and Development appropriation to carry out the 
purpose of Section 302 of the Federal Aviation Act of 1958, as amended 
(49 U.S.C. App. 1353) are excluded from this requirement. Only those 
contract actions obligating funds made available in appropriations after 
November 5, 1990, that have been authorized pursuant to 49 U.S.C. 106(k) 
and 506(a) of the Airport and Airway

[[Page 539]]

Improvement Act of 1982, are subject to this requirement.



PART 1227--PATENTS, DATA, AND COPYRIGHTS--Table of Contents




        Subpart 1227.3--Patent Rights Under Government Contracts

1227.305  Administration of patent rights clauses.
1227.305-4  Conveyance of invention rights acquired by the Government.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



        Subpart 1227.3--Patent Rights Under Government Contracts



1227.305  Administration of patent rights clauses.



1227.305-4  Conveyance of invention rights acquired by the Government.

    The contracting officer shall ensure that solicitations and 
contracts which include a patent rights clause include a means for the 
contractor to report inventions made in the course of contract 
performance and at contract completion. This requirement may be 
fulfilled by requiring the contractor to submit a DD Form 882, Report of 
Inventions and Subcontracts.
[59 FR 40281, Aug. 8, 1994]



PART 1228--BONDS AND INSURANCE--Table of Contents




                          Subpart 1228.1--Bonds

1228.106  Administration.
1228.106-1  Bonds and bond-related forms.
1228.106-6  Furnishing of information.
1228.106-70  Execution and administration of bonds.
1228-106-490  Contract clause. (USCG)

                        Subpart 1228.3--Insurance

1228.306  Insurance under fixed-price contracts.
1228.306-70  Contracts for lease of aircraft.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40281, Aug. 8, 1994, unless otherwise noted.



                          Subpart 1228.1--Bonds



1228.106  Administration.



1228.106-1  Bonds and bond-related forms.

    (c) SF 25, Performance Bond, prescribed at (FAR) 48 CFR 28.106-1(c), 
must provide coverage for taxes imposed by the United States which are 
collected, deducted, or withheld from wages paid by the contractor. 
Forms other than the SF 25 (e.g., a commercial form) shall not be used 
by contractors when a performance bond is required.



1228.106-6  Furnishing of information.

    (b) The contracting officer shall, upon request, furnish the name 
and address of the prime contractor's surety or sureties to employees, 
suppliers, and subcontractors having a contractual or employment 
relationship with prime contractors, subcontractors or suppliers. When 
furnishing surety information, the inquirer may also be informed that:
    (1) Persons believing that they have legal remedies under the Miller 
Act are cautioned to consult their own legal advisor regarding the 
proper steps to take to obtain remedies.
    (2) On construction contracts exceeding $2,000, if the contracting 
officer is informed (through routine compliance checking, a complaint, 
or a request for information) that a laborer, mechanic, apprentice, 
trainee, watchman, or guard employed by the contractor or subcontractor 
at any tier may have been paid wages less than those required by the 
applicable labor standards provisions of the contract, the contracting 
officer shall promptly initiate an investigation in accordance with 
(FAR) 48 CFR subpart 22.4, irrespective of the employee's rights under 
the Miller Act. When an employee's request for information is involved, 
the contracting officer shall inform the inquirer that such 
investigation will be made. Such investigation is required pursuant to 
the provisions of the Davis-Bacon Act, Contract Work Hours and Safety 
Standards Act, and Copeland (Anti-Kickback) Act for assuring proper 
payment to such employees.

[[Page 540]]

    (c) When furnishing a copy of a payment bond and contract in 
accordance with (FAR) 48 CFR 28.106-6(c), the requirement for a copy of 
the contract may be satisfied by furnishing a machine-duplicate copy of 
the contractor's first pages which show the contract number and date, 
the contractor's name and signature, the contracting officer's 
signature, and the description of the contract work. The contracting 
officer furnishing the copies shall place the statement ``Certified to 
be a true and correct copy'' followed by his/her signature, title and 
name of the OA. The fee for furnishing the requested certified copies 
shall be determined in accordance with the DOT Freedom of Information 
Act regulation, 49 CFR part 7, ((TAR) 48 CFR 1224.202).



1228.106-70  Execution and administration of bonds.

    (a) The surety shall be notified, as soon as feasible, of the 
contractor's failure to perform in accordance with the terms of the 
contract.
    (b) When a partnership is a principal on a bond, the names of all 
the members of the firm shall be listed in the bond following the name 
of the firm, and the phrase ``a partnership composed of.'' If a 
principal is a corporation, the state of incorporation must also appear 
on the bond.
    (c) Performance or payment bond other than an annual bond shall not 
antedate the contract to which it pertains.
    (d) Bonds shall be filed with the original contract to which they 
apply, or all bonds shall be separately maintained and reviewed 
quarterly for validity. If separately maintained, each contract file 
shall cross-reference the applicable bonds.



1228.106-490  Contract clause. (USCG)

    The contracting officer shall insert the USCG clause at (TAR) 48 CFR 
1252.228-90, Notification of Miller Act Payment Bond Protection, in 
solicitations and contracts, and shall require its first-tier 
subcontractors to insert the clause in all of their subcontracts, when 
payment bonds are required.



                        Subpart 1228.3--Insurance



1228.306  Insurance under fixed-price contracts.



1228.306-70  Contracts for lease of aircraft.

    (a) The contracting officer shall insert the clauses at (TAR) 48 CFR 
1252.228-70 through 1252.228-72, unless otherwise indicated by the 
specific instructions for their use, in any contract for the lease of 
aircraft (including aircraft used in out-service flight training).
    (b) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.228-70, Loss of or Damage to Leased Aircraft, in any contract for 
the lease of aircraft, except in the following circumstances:
    (1) When the hourly rental rate does not exceed $250 and the total 
rental cost for any single transaction is not in excess of $2,500;
    (2) When the cost of hull insurance does not exceed 10 percent of 
the contract rate; or
    (3) When the lessor's insurer does not grant a credit for uninsured 
hours, thereby preventing the lessor from granting the same to the 
Government.
    (c) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.228-71, Fair Market Value of Aircraft, when fair market value of 
the aircraft can be determined.
    (d) Section 504 of the Federal Aviation Act of 1958, as amended, 
provides that no lessor of an aircraft under a bona fide lease of 30 
days or more shall be liable by reason of his interest as lessor or 
title-holder of the aircraft for any injury to or death of persons, or 
damage to or loss of property, unless such aircraft is in the actual 
possession or control of such person at the time of such injury, death, 
damage or loss. On short-term or intermittent-use leases, however, the 
owner may be liable for damage caused by operation of the aircraft. It 
is usual for the aircraft owner to retain insurance covering this 
liability during the term of such lease. Such insurance can, often for 
little or no increase in premium, be made to cover the Government's 
exposure to liability as well. In order to take advantage of

[[Page 541]]

this coverage, the Risks and Indemnities clause at (TAR) 48 CFR 
1252.228-72 prescribed in paragraph (d)(1) of this section shall be 
used.
    (1) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.228-72, Risk and Indemnities, in any contract for out-service 
flight training or for the lease of aircraft when the Government will 
have exclusive use of the aircraft for a period of less than thirty 
days.
    (2) Any contract for out-service flight training shall include a 
clause in the contract schedule stating substantially that the 
contractor's personnel shall at all times during the course of the 
training be in command of the aircraft, and that at no time shall other 
personnel be permitted to take command of the aircraft.



PART 1231--CONTRACT COST PRINCIPLES AND PROCEDURES--Table of Contents




         Subpart 1231.2--Contracts With Commercial Organizations

1231.205  Selected costs.
1231.205-32  Precontract costs.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



         Subpart 1231.2--Contracts With Commercial Organizations



1231.205  Selected costs.



1231.205-32  Precontract costs.

    (a) The decision to incur precontract costs is that of the 
contractor. No DOT employee can authorize, demand, or require a 
contractor to incur precontract costs. The contracting officer may 
advise the prospective contractor that any costs incurred before 
contract award are at the contractor's sole risk and that if 
negotiations fail to result in a binding contract, payment of these 
costs may not be made by the Government.
    (b) When the contracting officer determines that incurring 
precontract costs was necessary to meet the proposed contract delivery 
schedule of a cost-reimbursement contract, the clause at (TAR) 48 CFR 
1252.231-70, Date of Incurrence of Costs, may be inserted in the 
resultant contract.
[59 FR 40282, Aug. 8, 1994]



PART 1232--CONTRACT FINANCING--Table of Contents




                   Subpart 1232.70--Contract Payments

1232.7002  Invoice and voucher review and approval.

Appendix A to Subpart 1232.70--Instructions for Completing the SF 1034
Appendix B to Subpart 1232.70--Instructions for Completing the SF 1035

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40282, Aug. 8, 1994, unless otherwise noted.



                   Subpart 1232.70--Contract Payments



1232.7002  Invoice and voucher review and approval.

    (a) Under fixed-price contracts, the contracting officer shall 
require the contractor to submit an invoice or voucher in order to 
receive payment under the contract. The invoice or voucher may be on a 
form or company letterhead as long as it meets the requirements of the 
Prompt Payment Act as implemented by OMB Circular A-125--Prompt Payment, 
(FAR) 48 CFR subpart 32.9, and the contract.
    (b) Under other than fixed-price contracts, the contracting office 
shall require the contractor to submit the SF 1034, Public Voucher for 
Purchases and Services Other Than Personal, and the SF 1035, Public 
Voucher for Purchases and Services Other Than Personal (Continuation 
Sheet), to request payments. The forms must be completed as required by 
Appendix A, Instructions for Completing the SF 1034, and Appendix B, 
Instructions for Completing the SF 1035.

 Appendix A to Subpart 1232.70--Instructions for Completing the SF 1034

    The SF 1034, Public Voucher for Purchases and Services Other Than 
Personal, shall be completed in accordance with the below instructions. 
The lettered items correspond to the entries on the form.

[[Page 542]]



                                                                        
------------------------------------------------------------------------
    Caption on the SF 1034          Data to be Inserted in the Block    
------------------------------------------------------------------------
1. U.S. Department, Bureau,    Name and address of the contracting      
 or establishment and           office which issued the contract.       
 location.                                                              
2. Date voucher prepared.....  Date voucher submitted to the designated 
                                billing office cited under the contract 
                                or order.                               
3. Contract no. and date.....  Contract No. and, when applicable, the   
                                Order No. and date as shown on the award
                                document.                               
4. Requisition no. and date..  Leave blank or fill-in in accordance with
                                the instructions in the contract.       
5. Voucher no................  Start with ``1'' and number              
                                consecutively. A separate series of     
                                consecutive numbers must be used        
                                beginning with ``1'' for each contract  
                                number or order number (when            
                                applicable). Note: Insert the word      
                                ``FINAL'' if this is the last voucher.  
6. Schedule No.; paid by;      Leave all these blocks blank.            
 date invoice received;                                                 
 discount terms; payee's                                                
 account no.; shipped from/                                             
 to; weight; government B/L.                                            
7. Payee's name and address..  Name and address of contractor as it     
                                appears on the contract. If the contract
                                is assigned to a bank, also show        
                                ``CONTRACT ASSIGNED'' below the name and
                                address of the contractor.              
8. Number and date of order..  Leave blank. (See #3 above.)             
9. Date of delivery or         The period for which the incurred costs  
 service.                       are being claimed (e.g., month and year;
                                beginning and ending date of services,  
                                etc.).                                  
10. Articles or services.....  Insert the following: ``For detail, see  
                                the total amount of the claim           
                                transferred from the attached SF 1035,  
                                page X of X.'' One space below this     
                                line, insert the following: ``COST      
                                REIMBURSABLE-PROVISIONAL PAYMENT.''     
11. Quantity; unit price;      Leave blank.                             
 (cost; per).                                                           
12. Amount...................  Insert the total amount claimed from the 
                                last page of the SF 1035.               
Payee must NOT use the space   Do NOT write or type below this line.    
 below..                                                                
------------------------------------------------------------------------

 Appendix B to Subpart 1232.70--Instructions for Completing the SF 1035

    The SF 1035, Public Voucher for Purchases and Services Other Than 
Personal (Continuation Sheet), shall be completed in accordance with the 
below instructions.
    1. Use the same basic instructions for the SF 1035 as used for the 
SF 1034. Ensure that the contract and, if applicable, order number, are 
shown on information required by the contract, contracting officer, or 
cognizant audit agency; however, if more than one sheet of SF 1035 is 
used, each sheet shall be in numerical sequence.
    2. The following items are generally entered below the line with 
Number and Date of Order; Date of Delivery or Service; Articles or 
Services; Quantity; Unit Price; and Amount (but do not necessarily tie 
to these captions).
    3. Description of data to be inserted as it applies to the contract 
or order number.
    a. Show, as applicable, the target or estimated costs, target or 
fixed-fee, and total contract value, as adjusted by any modifications to 
the contract or order. The FAR permits the contracting officer to 
withhold a percentage of fixed fee until a reserve is set aside in an 
amount that is considered necessary to protect the Government's 
interest.
    b. Show the following costs and supporting data (as applicable) to 
the contract or order:
    (1) Direct Labor. List each labor category, rate per labor hour, 
hours worked, and extended total labor dollars per labor category.
    (2) Premium Pay/Overtime. List each labor category, rate per labor 
hour, hours worked, and the extended total labor dollars per labor 
category. Note: Advance written authorization must be received from the 
contracting officer to work overtime or to pay premium rates; therefore, 
identify the contracting officer's written authorization to the 
contractor.
    (3) Fringe Benefits. If fringe benefits are included in the overhead 
pool, no entry is required. If the contract allows for a separate fringe 
benefit pool, cite the formula (rate and base) in effect during the time 
the costs were incurred. If the contract allows for billing fringe 
benefits as a direct expense, show the actual fringe benefit costs.
    (4) Materials, Supplies, Equipment. Show those items normally 
treated as direct costs. Expendable items need not be itemized and may 
be grouped into major classifications such as office supplies. However, 
items valued at $5,000 or more must be itemized. See (FAR) 48 CFR part 
45, Government Property, for reporting of property.
    (5) Travel. List the name and title of traveller, place of travel, 
and travel dates. If the travel claim is based on the actual costs 
expended, show the amount for the mode of travel (i.e., airline, private 
auto, taxi, etc.), lodging, meals, and other incidental expenses 
separately, on a daily basis. These actual costs must be supported with 
receipts to substantiate the costs paid. Travel costs for consultants 
must be shown separately and also supported.
    (6) Other Direct Costs. Itemize those costs that cannot be placed in 
categories (1) through (5) above. Categorize these costs to the extent 
possible.

[[Page 543]]

    (7) Total Direct Costs. Cite the sum of categories (1) through (6) 
above.
    (8) Overhead. Cite the rate, base, and extended amount.
    (9) G&A Expense. Cite the rate, base, and extended amount.
    (10) Total Costs. Cite the sum of categories (7) through (9) above.
    (11) Fee. Cite the rate, base, and extended amount.
    (12) Total Cost and Fee Claimed. Enter this amount on the SF 1034.

                           Completion Voucher

    The completion (final) voucher is the last voucher to be submitted 
for incurred, allocable, and allowable costs expended to perform the 
contract or order. This voucher should include all contract reserves, 
allowable cost withholdings, balance of fixed fee, etc. However, the 
amount of the completion voucher when added to the total amount 
previously paid cannot exceed the total amount of the contract.



PART 1233--PROTESTS, DISPUTES, AND APPEALS--Table of Contents




                  Subpart 1233.2--Disputes and Appeals

1233.211  Contracting officer's decision.
1233.214  Alternative dispute resolution.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



                  Subpart 1233.2--Disputes and Appeals



1233.211  Contracting officer's decision.

    For DOT contracts, the Board of Contract Appeals (BCA) referenced at 
(FAR) 48 CFR 33.211 is the Department of Transportation Board of 
Contract Appeals (S-20), 400 7th Street, S.W., Washington, DC, 20590. 
The DOTBCA Rules of Procedure are contained in 48 CFR chapter 63, part 
6301.
[59 FR 40283, Aug. 8, 1994]



1233.214  Alternative dispute resolution.

    (c) The Administrative Dispute Resolution Act (ADRA), Pub. L. 101-
552, authorizes and encourages agencies to use mediation, conciliation, 
arbitration, and other techniques for the prompt and informal resolution 
of disputes, and for other purposes. The DOTBCA Alternate Dispute 
Resolution (ADR) procedures are contained in 48 CFR chapter 63, section 
6302.30, ADR Methods (Rule 30), and will be distributed to the parties, 
if ADR procedures are used. These procedures may be obtained from the 
DOTBCA upon request. ADR procedures may be used when:
    (1) There is mutual consent by the parties to participate in the ADR 
process (with consent being obtained either before or after an issue in 
controversy has arisen);
    (2) Prior to the submission of a claim; and
    (3) In resolution of a formal claim.
    (d) DOT's Dispute Resolution Specialist in accordance with the ADRA 
is located in the DOT Office of the General Counsel, C-1. The Dispute 
Resolution Specialist performs the functions set forth in the 
Administrative Disputes Resolution Act for DOT operating administrations 
on a non-reimbursable basis. The Dispute Resolution Specialist may 
conduct any of the alternative means of dispute resolution set forth in 
Title 5, U.S.C. Section 581(3), including settlement negotiations under 
the auspices of a settlement judge, conciliation, facilitation, 
mediation, fact finding, mini-trials, and arbitration, or any 
combination of these methods.
[59 FR 40283, Aug. 8, 1994, as amended at 61 FR 50250, Sept. 25, 1996]



PART 1234--MAJOR SYSTEM ACQUISITION--Table of Contents




    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



1234.003  Responsibilities.

    DOT's internal procedures for implementing OMB Circular A-109, Major 
System Acquisitions, is contained in Chapter 1234, Appendix A, of the 
Transportation Acquisition Manual (which is stocked at the Government 
Printing Office).
[59 FR 40283, Aug. 8, 1994]



PART 1235--RESEARCH AND DEVELOPMENT CONTRACTING--Table of Contents




    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

[[Page 544]]



1235.003  Policy.

    (b) Cost sharing. DOT cost sharing policies shall be in accordance 
with (FAR) 48 CFR 16.303, (FAR) 48 CFR 42.707(a), and OA procedures.
[59 FR 40284, Aug. 8, 1994]



PART 1236--CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS--Table of Contents




   Subpart 1236.3--Special Aspects of Sealed Bidding in Construction 
                               Contracting

1236.305  Preconstruction conference.

                    Subpart 1236.5--Contract Clauses

1236.570  Special precautions for work at operating airports.

               Subpart 1236.6--Architect-Engineer Services

1236.602  Selection of firms for architect-engineer contracts.
1236.602-1  Selection criteria.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40284, Aug. 8, 1994, unless otherwise noted.



   Subpart 1236.3--Special Aspects of Sealed Bidding in Construction 
                               Contracting



1236.305  Preconstruction conference.

    When the contracting officer considers such action warranted, he/she 
shall arrange a preconstruction conference with the contractor and such 
subcontractors as the contractor may designate to assure that there is a 
clear understanding of the contract requirements (including labor 
standards provisions) and the rights and obligations of the parties.



                    Subpart 1236.5--Contract Clauses



1236.570  Special precautions for work at operating airports.

    Where any acquisition will require work at an operating airport, 
insert the clause at (TAR) 48 CFR 1252.236-70, Special Precautions for 
Work at Operating Airports, in solicitations and contracts.



               Subpart 1236.6--Architect-Engineer Services



1236.602  Selection of firms for architect-engineer contracts.



1236.602-1  Selection criteria.

    (a) Appropriate criteria in addition to those under (FAR) 48 CFR 
36.602-1(a) may include, but are not limited to, the criteria listed 
below. The extent to which these criteria are used will depend on the 
size and the complexity of the project. For instance, for small and 
straight-forward projects, particularly those under the small purchase 
limitation, the data provided by the SFs 254 and 255 may provide an 
adequate measure of the firm's experience and qualification required for 
the project. However, on large and more complex projects, the evaluation 
criteria should be extended to consider such factors as the firm's 
suggested design approach, methods, and design ability, such as:
    (1) Capability of the firm to accomplish the work: (i) Relevant, 
recent experience and technical knowledge of key project personnel and 
key outside consultants;
    (ii) Total number of personnel the Architect-Engineer (A-E) firm 
employs in the technical disciplines required for the proposed work.
    (2) Capacity of the firm to accomplish the work. In assessing the 
firm's capacity to accomplish the work in the required time, 
consideration shall be given to the firm's current workload, total 
number of ongoing projects, and percentage of completion.
    (3) Design ability and understanding of the requirements:
    (i) Technical approach (planning and design process, overall 
planning and design philosophy), possible concepts (narrative), special 
design opportunities, innovative design possibilities (including 
environmental), and provisions for the handicapped;
    (ii) Understanding of, and experience in, energy conservation 
design:
    (A) Approach to maximizing energy conservation;
    (B) Project building and equipment systems that would significantly 
impact energy consumption;

[[Page 545]]

    (C) Criteria and engineering considerations to be used in building 
and equipment design; and
    (D) Examples of previously used design techniques and measure of 
results (in BTUs consumed per square foot or energy costs);
    (iii) Proposed project schedule and personnel-loading plan;
    (iv) Quality of examples of previous work; and
    (v) Major awards and other major recognition the firm or members of 
the firm have received for design excellence.
    (4) Organization and management:
    (i) Project team organization and key personnel roles and 
responsibilities;
    (ii) Project management procedures such as coordination of design 
effort among technical disciplines;
    (iii) Methods used to control project schedule and construction cost 
estimates; and
    (iv) Quality control procedures.
    (5) Record of past performance:
    (i) Accuracy of construction cost estimates (compared to 
construction bids received and value of awarded construction 
contract(s);
    (ii) Number, dollar amount and reason for construction change 
orders, if any; and
    (iii) A-E/client relationship (for Government contracts, the above 
information is available from SF 1421, Performance Evaluation (A-E)).
    (b) If a design competition is to be used, written approval by the 
COCO shall be obtained prior to soliciting proposals.
    (c) The following evaluation criterion shall be used in the A-E 
evaluation process for A-E acquisitions above the small purchase 
limitation. The criterion shall be evaluated separately from other 
criteria and added to the basic evaluation rating for a composite 
rating.
    Minority and Women Employment--A criterion related to evaluating the 
number of minorities and women in all relevant job classifications and 
pay scales that will actually work on the project in comparison to the 
number of qualified minorities and women of the same job classification 
and pay scale located in the Standard Metropolitan Statistical Area 
(SMSA) where the work is to be performed.



PART 1237--SERVICE CONTRACTING--Table of Contents




               Subpart 1237.1--Service Contracts--General

1237.104  Personal services contracts. (USCG)
1237.104-90  Delegation of authority. (USCG)
1237.110  Solicitation provisions and contract clauses.

 Subpart 1237.70--Department of Transportation Procedures for Acquiring 
                            Training Services

1237.7000  Policy.
1237.7001  Certification of data.
1237.7002  Applicability.
1237.7003  Solicitation provision and contract clause.

                   Subpart 1237.90--Mortuary Services

1237.9000  Solicitation provisions and contract clauses. (USCG)

              Subpart 1237.104--Personal Services Contracts

1237.104-90  Delegation of authority. (USCG)

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.



               Subpart 1237.1--Service Contracts--General



1237.104  Personal services contracts. (USCG)



1237.104-90  Delegation of authority. (USCG)



1237.110  Solicitation provisions and contract clauses.

    Contracting officers shall insert the clause at (TAR) 48 CFR 
1252.237-70, Qualifications of Employees, in all solicitations and 
contracts for services which require contract performance at a 
Government facility.
[59 FR 40284, Aug. 8, 1994]



 Subpart 1237.70--Department of Transportation Procedures for Acquiring 
                            Training Services

    Source:  61 FR 391, Jan. 5, 1996, unless otherwise noted.

[[Page 546]]



1237.7000  Policy.

    When training services are provided under contract to DOT, it is the 
policy of DOT that all prospective contractors:
    (a) Certify that the data provided concerning company 
qualifications, background statements, etc., is current, accurate, and 
complete; and
    (b) Agree to not solicit or advertise private, non-Government 
training while conducting a training course.



1237.7001  Certification of data.

    Towards fulfilling DOT's policy at (TAR) 48 CFR 1237.7000(a), 
contracting officers shall request information from prospective 
contractors for certification purposes. The type of information 
requested is dependent upon the criticality of the service and/or any 
unique or essential qualification requirements.



1237.7002  Applicability.

    The policy at (TAR) 48 CFR 1237.7000 applies to all DOT contracts as 
defined in FAR 2.101 for training services when DOT controls the content 
and/or presentation of the course. This policy does not apply to courses 
attended by DOT employees which are offered and sponsored by Government 
sources of supply, educational institutions, or private entities where 
DOT does not control the course content or presentation. (See (TAR) 48 
CFR 1213.7100 for examples.)



1237.7003  Solicitation provision and contract clause.

    (a) The contracting officer shall insert the provision at (TAR) 48 
CFR 1252.237-71, Certification of Data, in solicitations and the clause 
at (TAR) 48 CFR 1252.237-72, Prohibition on Advertising, in 
solicitations and contracts for training services when the content and/
or presentation of the course is controlled by DOT.
    (b) Contracting officers shall incorporate the successful offeror's 
certified data into any resultant contract(s). Certified data may be 
incorporated by reference, if the contracting officer determines it 
contains sufficient descriptive information (i.e., dated material such 
as resumes, company and/or personnel qualifications) to reliably 
describe the certified data submitted.



                   Subpart 1237.90--Mortuary Services



1237.9000  Solicitation provisions and contract clauses. (USCG).

    (a) The contracting officer shall insert the following clauses in 
solicitations and contracts for mortuary services. However, USCG clauses 
(TAR) 48 CFR 1252.237-91 and 1252.237-97 shall not be inserted in 
solicitations and contracts that include port of entry requirements:
    (1) (TAR) 48 CFR 1252.237-90, Requirements;
    (2) (TAR) 48 CFR 1252.237-91, Area of Performance;
    (3) (TAR) 48 CFR 1252.237-92, Performance and Delivery;
    (4) (TAR) 48 CFR 1252.237-93, Subcontracting;
    (5) (TAR) 48 CFR 1252.237-94, Termination for Default;
    (6) (TAR) 48 CFR 1252.237-95, Group Interment;
    (7) (TAR) 48 CFR 1252.237-96, Permits;
    (8) (TAR) 48 CFR 1252.237-97, Facility Requirements; and
    (9) (TAR) 48 CFR 1252.237-98, Preparation History.
    (b) The contracting officer shall insert USCG provision (TAR) 48 CFR 
1252.237-99, Award to Single Offeror, in all sealed bid solicitations 
for mortuary services. Use the basic provision with Alternate I in 
negotiated solicitations for mortuary services.
    (c) The contracting officer shall insert (FAR) 48 CFR 52.245-4, 
Government-Furnished Property (Short Form) in solicitations and 
contracts that include port of entry requirements.
[59 FR 40284, Aug. 8, 1994]



              Subpart 1237.104--Personal Services Contracts



1237.104-90  Delegation of authority. (USCG)

    (a) Pub. L. 104-106, DOD Authorization Act of 1996, Section 733, 
added Section 1091(A) to Title 10 of the United States Code, which 
authorizes contracting authority for personal service contracts for 
medical treatment facilities for the Coast Guard.
    (b) The authority of the Secretary of Transportation under Pub. L. 
104-106 to

[[Page 547]]

contract for personal service contracts for medical treatment facilities 
for the Coast Guard is delegated to the HCA with the authority to 
redelegate to contracting officers under procedures established by the 
Head of Contracting Activity, who will address applicable statutory 
limitations under Section 1091 of Title 10 U.S.C.
[61 FR 50250, Sept. 25, 1996]



PART 1242--CONTRACT ADMINISTRATION--Table of Contents




          Subpart 1242.2--Assignment of Contract Administration

1242.203  Retention of contract administration.
1242.203-70  Contract clauses.
1242.205  Designation of the paying office.

        Subpart 1242.3--Contract Administration Office Functions

1242.302  Contract administration functions.

     Subpart 1242.70--Contracting Officer's Technical Representative

1242.7000  Contract clause.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40285, Aug. 8, 1994, unless otherwise noted.



          Subpart 1242.2--Assignment of Contract Administration



1242.203  Retention of contract administration.

    (a) Contracting offices may obtain contract administration 
assistance from the Defense Logistics Agency (DLA), Defense Contract 
Management Command, Alexandria, VA, when the contracting officer 
determines that such action is to be in the best interest of DOT.



1242.203-70  Contract clauses.

    (a) The contracting officer may use the clause at (TAR) 48 CFR 
1252.242-70, Dissemination of Information--Educational Institutions, in 
lieu of the clause at (TAR) 48 CFR 1252.242-72, Dissemination of 
Contract Information, in DOT research contracts with educational 
institutions, except contracts that require the release or coordination 
of information.
    (b) The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.242-71, Contractor Testimony, in all solicitations and contracts 
issued by NHTSA. Other OAs may use the clause as deemed appropriate.
    (c) The contracting officer may insert the clause at (TAR) 48 CFR 
1252.242-72, Dissemination of Contract Information, in all DOT contracts 
except contracts that require the release or coordination of 
information.



1242.205  Designation of the paying office.

    (a) The assignment of contract administration to a DLA Contract 
Administration Office (CAO) by the contracting officer does not affect 
the designation of the paying office unless a transfer of DOT funds to 
the agency of the CAO is effected, and the funds are converted to the 
agency's account for payment purposes.
    (b) When the contracting officer proposes to delegate the contract 
payment function to another agency (e.g., DLA), the contracting officer 
shall discuss the transfer of funds procedures with the OA cognizant 
payment office.



        Subpart 1242.3--Contract Administration Office Functions



1242.302  Contract administration functions.

    (a)(13) The CAO, or the contracting officer's designee under fixed 
price contracts, shall review and approve the contractor's invoice for 
payment. The CAO shall review and approve contractors' vouchers under 
cost-reimbursement contracts, and this function cannot be delegated to a 
COTR. All payments to contractors will be made by the payment office 
designated in the contract to make payments.



     Subpart 1242.70--Contracting Officer's Technical Representative



1242.7000  Contract clause.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.242-73,

[[Page 548]]

Contracting Officer's Technical Representative, in solicitations and 
contracts when it is intended that a representative will be assigned to 
the contract to perform functions of a technical nature.



PART 1245--GOVERNMENT PROPERTY--Table of Contents




 Subpart 1245.5--Management of Government Property in the Possession of 
                               Contractors

1245.505  Records and reports of Government property.
1245.505-14  Reports of Government property.
1245.505-70  Solicitation provisions and contract clauses.
1245.508-2  Reporting results of inventories.
1245.508-3  Quantitative and monetary control.
1245.511  Audit of property control system.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40285, Aug. 8, 1994, unless otherwise noted.



 Subpart 1245.5--Management of Government Property in the Possession of 
                               Contractors



1245.505  Records and reports of Government property.



1245.505-14  Reports of Government property.

    When Government property is furnished to or acquired by the 
contractor to perform the contract, the contract shall require the 
contractor to submit annual reports (see (FAR) 48 CFR 45.505-14) to the 
contracting officer not later than September 15 of each year. The 
contractor's report shall be submitted on Form DOT F 4220.43, Contractor 
Report of Government Property.



1245.505-70  Solicitation provisions and contract clauses.

    Contracting officers shall insert the clause at (TAR) 48 CFR 
1252.245-70 in solicitations and contracts when the contract will 
require Government provided or contractor acquired property.



1245.508-2  Reporting results of inventories.

    The inventory report shall also include the following:
    (a) Name and title of the individual(s) that performed the physical 
inventory;
    (b) An itemized, categorized listing of all property capitalized:
    (1) Land and rights therein;
    (2) Other real property;
    (3) Plant equipment;
    (4) Special test equipment; and
    (5) Special tooling;
    (c) An itemized listing of the property lost, damaged, destroyed, or 
stolen, the circumstances surrounding each incident, and the resolution 
of the incident; and
    (d) Any discrepancies between the physical inventory and the 
contractor's record of Government property.



1245.508-3  Quantitative and monetary control.

    Contracting officers shall require the contractor to provide the 
quantity and unit cost of each item of Government property reported 
under (TAR) 48 CFR 1245.508-2(b) and (c).



1245.511  Audit of property control system.

    (a) The property administrator (or other Government official 
authorized by the contracting officer) shall audit the contractor's 
property control system whenever there are indications that the 
contractor's property control system may be deficient. Examples of 
deficiencies are:
    (1) Failure of the contractor to acknowledge receipt of GFP;
    (2) Failure of the contractor to submit the annual property reports 
required by (TAR) 48 CFR 1245.505-14;
    (3) Failure of the contractor to reconcile its physical inventory 
with its property control record; or
    (4) Failure of the contractor to submit a Government property 
listing when requested by the property administrator.
    (b) When it is determined that the contractor's property control 
system is deficient, the property administrator, in coordination with 
the contracting officer, shall discuss the deficiencies with the 
contractor. If the contractor

[[Page 549]]

does not take action to correct the deficiencies, the contracting 
officer shall provide the contractor with a written notice of the 
deficiencies and the date all deficiencies must be corrected.



PART 1246--QUALITY ASSURANCE--Table of Contents




                       Subpart 1246.7--Warranties

1246.701  Definitions.
1246.701-70  Additional definitions.
1246.701-90  Additional USCG definitions. (USCG)
1246.703  Criteria for use of warranties.
1246.705  Limitations.
1246.706  Warranty terms and conditions.
1246.790  Use of warranties in major system acquisitions by the USCG. 
          (USCG)
1246.790-1  Policy. (USCG)
1246.790-2  Tailoring warranty terms and conditions. (USCG)
1246.790-3  Warranties on Government-furnished property. (USCG)
1246.791  Cost benefit analysis. (USCG)
1246.792  Waiver and notification procedures. (USCG)

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40286, Aug. 8, 1994, unless otherwise noted.



                       Subpart 1246.7--Warranties



1246.701  Definitions.



1246.701-70  Additional definitions.

    At no additional cost to the Government means at no increase in 
price for firm-fixed-price contracts, at no increase in target or 
ceiling price for fixed price incentive contracts (see (FAR) 48 CFR 
46.707), or at no increase in estimated cost or fee for cost-
reimbursement contracts.
    Defect means any condition or characteristic in any supplies or 
services furnished by the contractor under the contract that is not in 
compliance with the requirements of the contract.
    Design and manufacturing requirements means structural and 
engineering plans and manufacturing particulars, including precise 
measurements, tolerances, materials and finished product tests for the 
major system being produced.
    Major system means a system or major subsystem used directly by DOT 
to carry out its mission(s), as defined by TAM Chapter 1234, Major 
Acquisition Policies and Procedures (for dollar threshold applicable to 
U.S. Coast Guard, See Coast Guard guidance at (TAR) 48 CFR 1246.701-90). 
The term does not include:
    (a) Related support equipment, such as ground-handling equipment, 
training devices and accessories thereto, unless a cost effective 
warranty for the system would require inclusion of such items; or
    (b) Commercial items sold in substantial quantities to the general 
public as described in (FAR) 48 CFR 15.804-1.
    Performance requirements means the operating capabilities, 
maintenance, and reliability characteristics of a system that are 
determined to be necessary for it to fulfill the requirement for which 
the system is designed.
[59 FR 40286, Aug. 8, 1994, as amended at 62 FR 26420, May 14, 1997]



1246.701-90  Additional USCG definitions. (USCG)

    For the USCG, in accordance with Public Law 99-190, the dollar 
threshold as it pertains to the inclusion of a warranty in major systems 
acquisitions is $10 million.



1246.703  Criteria for use of warranties.

    (a) Major systems. The use of warranties in the procurement of major 
systems by the USCG is mandatory, unless waived (see USCG guidance at 
(TAR) 48 CFR 1246.792). Other OAs may use the procedures in USCG 
guidance in this part as a guideline for major systems acquisitions.
    (b) Other systems. (1) Acquisition of warranties in the procurement 
of supplies that do not meet the definition of a major system (e.g., 
spare, repair, or replenishment parts) is governed by (FAR) 48 CFR 
46.703.
    (2) Contracting officers should negotiate a warranty that meets or 
exceeds the requirements of (TAR) 48 CFR 1246.706 when it is 
advantageous.



1246.705  Limitations.

    (a) The following restrictions are applicable to DOT contracts:
    (1) The USCG is the only DOT OA which is required to include a 
warranty in cost reimbursement contracts for

[[Page 550]]

the production of major systems acquisitions.
    (2) Any warranty on major system acquisitions shall not apply in the 
case of any system or component thereof which has been furnished by the 
Government to a contractor except as indicated in the USCG guidance at 
(TAR) 48 CFR 1246.790-3.
    (3) Any warranty obtained shall specifically exclude coverage of 
combat damage.



1246.706  Warranty terms and conditions.

    (a) The contracting officer, in developing the warranty terms and 
conditions, shall consider the following, and, where appropriate and 
cost beneficial, shall:
    (1) Identify the affected line item(s) and the applicable 
specification(s);
    (2) Require that the line item's design and manufacture will conform 
to: (i) an identified revision of a top-level drawing; and/or (ii) an 
identified specification or revision thereof;
    (3) Require that the system conform to the specified Government 
performance requirements;
    (4) Require that all systems and components delivered under the 
contract will be free from defects in materials and workmanship;
    (5) State that in the event of failure due to nonconformance with 
specification and/or defects in material and workmanship, the contractor 
will bear the cost of all work necessary to achieve the specified 
performance requirements, including repair and/or replacement of all 
parts;
    (6) Require the timely replacement/repair of warranted items and 
specify lead times for replacement/repair where possible;
    (7) Identify the specific paragraphs containing Government 
performance requirements which must be met;
    (8) Ensure that any performance requirements identified as goals or 
objectives in excess of specification requirements are excluded from the 
warranty provision;
    (9) Define what constitutes the start of the warranty period (e.g., 
delivery, acceptance, in-service date), the ending of the warranty 
(e.g., passing a test or demonstration, or operation without failure for 
a specified time period), and circumstances requiring an extension of 
warranty duration (e.g., extending the warranty period as a result of 
mass defect correction during warranty period);
    (10) Identify what transportation costs will be paid by the 
contractor in conjunction with warranty coverage;
    (11) Identify any conditions which will not be covered by the 
warranty, other than the exclusion of combat damage; and
    (12) Identify any limitation on the total dollar amount of the 
contractor's warranty exposure, or agreement to share costs after a 
certain dollar threshold to avoid unnecessary warranty returns.
    (b) Any contract that contains a warranty clause must contain 
warranty implementation procedures, including warranty notification 
content and procedures, and identify the individuals responsible for 
implementation of warranty provisions. The contract may also permit the 
contractor's participation in investigation of system failures, 
providing that the contractor is reimbursed at established rates for 
fault isolation work, and that the Government receive credit for any 
payments where equipment failure is covered by warranty provisions.



1246.790  Use of warranties in major systems acquisitions by the USCG. (USCG)

    This subpart sets forth the policy for the USCG to use in obtaining 
warranties from contractors when contracting for the acquisition of a 
major system.



1246.790-1  Policy. (USCG)

    The USCG shall include a warranty in all contracts for major systems 
acquisitions. When drafting warranty provisions/clauses for major 
systems acquisitions, the contracting officer shall ensure that the 
items listed at (TAR) 48 CFR 1246.706 have been considered. The warranty 
shall also meet the following requirements:
    (a) For systems or components which are commercially available, such 
warranty as is normally provided by the manufacturer or supplier shall 
be obtained in accordance with (FAR) 48

[[Page 551]]

CFR 46.703(d) and (FAR) 48 CFR 46.710(b)(2).
    (b) For systems or components provided in accordance with either 
design and manufacturing or performance requirements as specified in the 
contract or any modification to that contract, a warranty of compliance 
with the stated requirements shall be obtained.
    (c) The warranty provided under paragraph (b) of this section shall 
provide that in the event the major system or any component thereof 
fails to meet the terms of the warranty provided, the contracting 
officer may:
    (1) Require the contractor to promptly take such corrective action 
as the contracting officer determines to be necessary at no additional 
cost to the Government, including repairing or replacing all parts 
necessary to achieve the requirements set forth in the contract;
    (2) Require the contractor to pay costs reasonably incurred by the 
United States in taking necessary corrective action; or
    (3) Equitably reduce the contract price.
    (d) Any warranty shall specifically exclude coverage of combat 
damage.



1246.790-2  Tailoring warranty terms and conditions. (USCG)

    (a) As the objectives and circumstances vary considerably among 
major systems acquisition programs, contracting officers shall 
appropriately tailor the warranty on a case-by-case basis, including 
remedies, exclusions, limitations and durations, provided the tailoring 
is consistent with the specific requirements of this subpart and (FAR) 
48 CFR 46.706.
    (b) Contracting officers of major systems acquisitions may exclude 
from the terms of the warranty certain defects for specified supplies 
(exclusions) and may limit the contractor's liability under the terms of 
the warranty (limitations), as appropriate, if necessary to derive a 
cost-effective warranty in light of the technical risk, contractor 
financial risk, or other program uncertainties.
    (c) Contracting officers are encouraged to structure a broader and 
more comprehensive warranty where such is advantageous. Likewise, the 
contracting officer may narrow the scope of a warranty when appropriate 
(e.g., where it would be inequitable to require a warranty of all 
performance requirements because a contractor had not designed the 
system).
    (d) Contracting officers shall not include in a warranty clause any 
terms that require the contractor to incur liability for loss, damage, 
or injury to third parties.



1246.790-3  Warranties on Government-furnished property. (USCG)

    A contractor for a major systems acquisition shall not be required 
to provide the warranties specified in (TAR) 48 CFR 1246.790-1 on any 
property furnished to that contractor by the Government except for:
    (a) Defects in installation; and
    (b) Installation or modification in such a manner that invalidates a 
warranty provided by the manufacturer of the property.



1246.791  Cost benefit analysis. (USCG)

    Warranties shall be obtained for a major systems acquisition only 
when it is cost beneficial in accordance with TAM (Copies of the 
Transportation Acquisition Manual may be obtained from the Government 
Printing Office) 1246.703. If a specific warranty is considered not to 
be cost beneficial by the contracting officer, a waiver request shall be 
initiated in accordance with USCG guidance at 48 CFR 1246.792.



1246.792  Waiver and notification procedures. (USCG)

    (a) The Secretary of Transportation, without delegation, may waive 
the requirement for a warranty for USCG major system acquisitions when 
the waiver is in the interest of national defense or if the warranty 
obtained would not be cost beneficial. A waiver may be granted provided 
that the Committees on Appropriations of the Senate and the House of 
Representatives, the Committee on Commerce, Science and Transportation 
of the Senate, and the Committee on Merchant Marine and Fisheries of the 
House of Representatives are notified, in writing, of the Secretary's 
intention to waive the warranty requirements and the reasons supporting 
such a determination prior

[[Page 552]]

to granting the waiver. The request for Secretarial waiver shall 
include, at a minimum:
    (1) A brief description of the major system and its stage of 
production (e.g., the number of units delivered and anticipated to be 
delivered during the life of the program);
    (2) The specific waiver requested, the duration of the waiver if it 
is to involve more than one contract, and the rationale for the waiver; 
and
    (3) All documentation supporting the request for waiver, such as a 
cost-benefit analysis.
    (b) The waiver request shall be forwarded to the Secretary, via the 
Office of Acquisition and Grant Management (M-60). The USCG shall 
maintain a written record of each waiver granted and the Congressional 
notification and report made, together with supporting documentation.



PART 1247--TRANSPORTATION--Table of Contents




                         Subpart 1247.1--General

1247.104-370  Contract clause.

           Subpart 1247.3--Transportation in Supply Contracts

1247.305  Solicitation provisions, contract clauses, and transportation 
          factors.
1247.305-70  Solicitation provisions.
1247.305-71  Contract clause.

        Subpart 1247.5--Ocean Transportation by U.S.-Flag Vessels

1247.506  Procedures.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40287, Aug. 8, 1994, unless otherwise noted.



                         Subpart 1247.1--General



1247.104-370  Contract clause.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.247-70, Acceptable Service at Reduced Rates, to implement the 
requirements of (FAR) 48 CFR 47.104-3.
[59 FR 40287, Aug. 8, 1994, as amended at 61 FR 50250, Sept. 25, 1996]



           Subpart 1247.3--Transportation in Supply Contracts



1247.305  Solicitation provisions, contract clauses, and transportation factors.



1247.305-70  Solicitation provisions.

    The contracting officer shall insert the following provisions in 
solicitations, as applicable:
    (a) (TAR) 48 CFR 1252.247-71, F.o.b. Origin Information, with 
Alternates I or II, as applicable, shall be inserted in accordance with 
(FAR) 48 CFR 47.305-3(b);
    (b) (TAR) 48 CFR 1252.247-72, F.o.b. Origin Only, shall be inserted 
in accordance with (FAR) 48 CFR 47.305-3(e);
    (c) (TAR) 48 CFR 1252.247-73, F.o.b. Destination Only, shall be 
inserted in accordance with (FAR) 48 CFR 47.305-4(b);
    (d) (TAR) 48 CFR 1252.247-74, Shipments to Ports and Air Terminals, 
with Alternates I, II, and III, shall be inserted in accordance with 
(FAR) 48 CFR 47.305-6(a)(1) through (a)(4);
    (e) (TAR) 48 CFR 1252.247-75, F.o.b. Designated Air Carrier's 
Terminal, Point of Exportation, implements the requirements of (FAR) 48 
CFR 47.305-6(a)(5); and
    (f) (TAR) 48 CFR 1252.247-76, Nomination of Additional Ports, 
implements the requirements of (FAR) 48 CFR 47.305-6(d).
[59 FR 40287, Aug. 8, 1994, as amended at 61 FR 50250, Sept. 25, 1996]



1247.305-71  Contract clause.

    The contracting officer shall insert the clause at (TAR) 48 CFR 
1252.247-77, Supply Movement in the Defense Transportation System, in 
contracts to implement the requirements of (FAR) 48 CFR 47.305-6(f)(1).
[59 FR 40287, Aug. 8, 1994, as amended at 61 FR 50250, Sept. 25, 1996]



        Subpart 1247.5--Ocean Transportation by U.S.-Flag Vessels



1247.506  Procedures.

    (d) Reports concerning cargo preference shipments/ocean shipments 
(see

[[Page 553]]

(FAR) 48 CFR 47.506(d)) shall, as a minimum, contain the information and 
follow the procedures within subparagraph (c) of (FAR) 48 CFR 52.247-64, 
Preference for Privately Owned U.S.-Flag Commercial Vessels.



PART 1252--SOLICITATION PROVISIONS AND CONTRACT CLAUSES--Table of Contents




      Subpart 1252.1--Instructions for Using Provisions and Clauses

1252.101  Using part 1252.

             Subpart 1252.2--Texts of Provisions and Clauses

1252.209-70  Disclosure of conflicts of interest.
1252.210-90  Bar coding requirement. (USCG)
1252.211-70  Brand name or equal.
1252.211-71  Index for specifications.
1252.213-90  Evaluation factor for Coast Guard performance of bar coding 
          requirement. (USCG)
1252.215-70  Key personnel and/or facilities.
1252.216-70  Evaluation of offers subject to an economic price 
          adjustment clause.
1252.216-71  Determination of award fee.
1252.216-72  Performance evaluation plan.
1252.216-73  Distribution of award fee.
1252.216-74  Settlement of letter contract.
1252.217-71  Delivery and shifting of vessel.
1252.217-72  Performance.
1252.217-73  Inspection and manner of doing work.
1252.217-74  Subcontracts.
1252.217-75  Lay days.
1252.217-76  Liability and insurance.
1252.217-77  Title.
1252.217-78  Discharge of liens.
1252.217-79  Delays.
1252.217-80  Department of Labor safety and health regulations for ship 
          repairing.
1252.217-81  Guarantee.
1252.219-70  Small business and small disadvantaged business 
          subcontracting reporting.
1252-220-90  Local hire. (USCG)
1252.222-70  Strikes or picketing affecting timely completion of the 
          contract work.
1252.222-71  Strikes or picketing affecting access to a DOT facility.
1252.223-70  Removal or disposal of hazardous substances--applicable 
          licenses and permits.
1252.223-71  Accident and fire reporting.
1252.223-72  Protection of human subjects.
1252.225-90  Buy American Certificate--steel and manufactured products. 
          (FAA)
1252.225-91  Buy American--steel and manufactured products. (FAA)
1252.228-70  Loss of or damage to leased aircraft.
1252.228-71  Fair market value of aircraft.
1252.228-72  Risk and indemnities.
1252.228-90  Notification of Miller Act payment bond protection. (USCG)
1252.231-70  Date of incurrence of costs.
1252.236-70  Special precautions for work at operating airports.
1252.237-70  Qualifications of employees.
1252.237-71  Certification of data.
1252.237-72  Prohibition on advertising.
1252.237-90  Requirements. (USCG)
1252.237-91  Area of performance. (USCG)
1252.237-92  Performance and delivery. (USCG)
1252.237-93  Subcontracting. (USCG)
1252.237-94  Termination for default. (USCG)
1252.237-95  Group interment. (USCG)
1252.237-96  Permits. (USCG)
1252.237-97  Facility requirements. (USCG)
1252.237-98  Preparation history. (USCG)
1252.237-99  Award to single offeror. (USCG)
1252.242-70  Dissemination of information--educational institutions.
1252.242-71  Contractor testimony.
1252.242-72  Dissemination of contract information.
1252.242-73  Contracting officer's technical representative.
1252.245-70  Government property reports.
1252.247-70  Acceptable service at reduced rates.
1252.247-71  F.o.b. origin information.
1252.247-72  F.o.b. origin only.
1252.247-73  F.o.b. destination only.
1252.247-74  Shipments to ports and air terminals.
1252.247-75  F.o.b. designated air carrier's terminal, point of 
          exportation.
1252.247-76  Nomination of additional ports.
1252.247-77  Supply movement in the Defense Transportation System.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40288, Aug. 8, 1994, unless otherwise noted.



      Subpart 1252.1--Instructions for Using Provisions and Clauses



1252.101  Using part 1252.

    (b) Numbering--(2)(i) Provisions or clauses that supplement the FAR. 
(A) Agency-prescribed provisions and clauses permitted by TAR and used 
on a standard basis (i.e., normally used in two or more solicitations or 
contracts regardless of contract type) shall be prescribed and contained 
in the TAR. OAs desiring to use a provision or a clause on a standard 
basis shall submit a request containing a copy of the clause(s), 
justification for its use, and evidence of legal counsel review to M-

[[Page 554]]

60 in accordance with (TAR) 48 CFR 1201.304 for possible inclusion in 
the TAR.
    (B) Provisions and clauses used on a one-time basis (i.e., non-
standard provisions and clauses) may be approved by the contracting 
officer, unless a higher level is designated by the OA. This authority 
is permitted subject to:
    (1) evidence of legal counsel review in the contract file;
    (2) inserting these clauses in the appropriate sections of the 
uniform contract format; and
    (3) ensuring the provisions and clauses do not deviate from the 
requirements of the FAR and TAR.



             Subpart 1252.2--Texts of Provisions and Clauses



1252.209-70  Disclosure of conflicts of interest.

    As prescribed in 1209.507, insert the following provision:

             Disclosure of Conflicts of Interest (Oct 1994)

    It is the Department of Transportation's (DOT) policy to award 
contracts to only those offerors whose objectivity is not impaired 
because of any related past, present, or planned interest, financial or 
otherwise, in organizations regulated by DOT or in organizations whose 
interests may be substantially affected by Departmental activities. 
Based on this policy:
    (a) The offeror shall provide a statement in its proposal which 
describes in a concise manner all past, present or planned 
organizational, financial, contractual or other interest(s) with an 
organization regulated by DOT, or with an organization whose interests 
may be substantially affected by Depart-mental activities, and which is 
related to the work under this solicitation. The interest(s) described 
shall include those of the proposer, its affiliates, proposed 
consultants, proposed subcontractors and key personnel of any of the 
entities. Past interest shall be limited to within one year of the date 
of the offeror's technical proposal. Key personnel shall include any 
person owning more than 20% interest in the offeror, and the offeror's 
corporate officers, its senior managers and any employee who is 
responsible for making a decision or taking an action on this contract 
where the decision or action can have an economic or other impact on the 
interests of a regulated or affected organization.
    (b) The offeror shall describe in detail why it believes, in light 
of the interest(s) identified in paragraph (a) of this section, that 
performance of the proposed contract can be accomplished in an impartial 
and objective manner.
    (c) In the absence of any relevant interest identified in paragraph 
(a) of this section, the offeror shall submit in its proposal a 
statement certifying that to its best knowledge and belief no 
affiliation exists relevant to possible conflicts of interest. The 
offeror must obtain the same information from potential subcontractors 
prior to award of a subcontract.
    (d) The Contracting Officer will review the statement submitted and 
may require additional relevant information from the offeror. All such 
information, and any other relevant information known to DOT, will be 
used to determine whether an award to the offeror may create a conflict 
of interest. If any such conflict of interest is found to exist, the 
Contracting Officer may (1) disqualify the offeror, or (2) determine 
that it is otherwise in the best interest of the United States to 
contract with the offeror and include appropriate provisions to mitigate 
or avoid such conflict in the contract awarded.
    (e) The refusal to provide the disclosure or representation, or any 
additional information required, may result in disqualification of the 
offeror for award. If nondisclosure or misrepresentation is discovered 
after award, the resulting contract may be terminated. If after award 
the Contractor discovers a conflict of interest with respect to the 
contract awarded as a result of this solicitation, which could not 
reasonably have been know prior to award, an immediate and full 
disclosure shall be made in writing to the Contracting Officer. The 
disclosure shall include a full description of the conflict, a 
description of the action the contractor has taken, or proposes to take, 
to avoid or mitigate such conflict. The Contracting Officer may, 
however, terminate the contract for convenience if he or she deems that 
termination is in the best interest of the Government.

(End of provision)



1252.210-90  Bar coding requirement. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1210.011-90 and 
1213.507-90, insert the following clause:

                   Bar Coding Requirements (Oct 1994)

    Item markings shall include bar coding in accordance with MIL-STD-
1189 as follows:
    (a) The stock number shall be bar coded with no prefixes, dashes, 
spaces, or suffixes encoded. The contract number, the delivery order, or 
call order number, when used, shall be bar coded with no spaces or 
dashes encoded.
    (b) Prefixes and suffixes to the stock number may be included in the 
OCR-A in-the-clear markings, but not in the bar code.

[[Page 555]]

    (c) Preferred Bar Code Density (characters per inch as defined in 
MIL-STD-1189) is ``standard,'' but densities from ``standard'' to 
``low'' are acceptable.
    (d) OCR-A characters do not have to be machine readable.
    (e) Bar coding shall be machine readable.
    (f) Unless otherwise specified herein, minimum bar code height shall 
be 0.25 inch (6.4 mm) or 15 percent of the bar code length, whichever is 
greater.
    (g) The preferred position of the OCR-A characters is beneath the 
bar codes, but the OCR-A characters may be over the bar codes.
    (h) On outer containers contractors shall either:
    (1) Encode the stock numbers and contract number in one line of bar 
code with the stock number appearing first; or
    (2) Encode the item stock number and contract number on two labels, 
with the top label containing the stock number and the lower label 
containing the contract number.
    (i) On unit and intermediate containers, the item stock number in 
bar code with OCR-A below may be on the same label as the other data 
(identification markings) required by MIL-STD-129H. However, the bar 
code stock number shall appear on the top line with OCR-A characters on 
the second line; the OCR-A characters may include the stock number 
prefix and suffix, or alternatively, the complete stock number including 
any prefix and suffix, shall be repeated as part of the identification 
markings.
    (j) Exclusions from bar code markings are:
    (1) Multi-packs/consolidation containers (containers with two or 
more different stock numbers within).
    (2) Reusable shipping containers used for multiple/ different stock 
number applications.
    (3) Items consigned to a prime contractor's plant for installation 
in production.

                             (End of clause)



1252.211-70  Brand name or equal.

    As prescribed in (TAR) 48 CFR 1210.011, insert the following 
provision:

                     Brand Name or Equal (Oct 1994)

    (As used in this provision, the term ``brand name'' includes 
identification of products by make and model.)
    (a) If items called for by this solicitation have been identified in 
the schedule by a ``brand name or equal'' description, such 
identification is intended to be descriptive, but not restrictive, and 
is intended to indicate the quality and characteristics of products that 
will be satisfactory. Offers offering ``equal'' products (including 
products of the brand name manufacturer other than the one described by 
brand name) will be considered for award if such products are clearly 
identified in the offers and are determined by the Government to meet 
fully the salient characteristic requirements listed in the 
solicitation.
    (b) Unless the offeror clearly indicates in its offer that it is 
offering an ``equal'' product, its offer shall be considered as offering 
the brand name product referenced in the solicitation.
    (c) If the offeror proposed to furnish an ``equal'' product, the 
brand name, if any, of the product to be furnished shall be inserted in 
the space provided in the solicitation, or such product shall be 
otherwise clearly identified in the offer. The evaluation of offers and 
the determination as to equality of the product offered shall be the 
responsibility of the Government and will be based on information 
furnished by the offeror or identified in its offer as well as other 
information reasonably available to the contracting office. CAUTION TO 
OFFERORS: The contracting office is not responsible for locating or 
securing any information which is not identified in the offer and 
reasonably available to the contracting office. Accordingly, to insure 
that sufficient information is available, the offeror must furnish as a 
part of its offer all descriptive material (such as cuts, illustrations, 
drawings, or other information) necessary for the contracting office to: 
(1) determine whether the product offered meets the salient 
characteristic requirements of the solicitation; and (2) establish 
exactly what the offeror proposes to furnish and what the Government 
would be binding itself to acquire by making an award. The information 
furnished may include specific reference to information previously 
furnished or to information otherwise available to the contracting 
office.
    (d) If the offeror proposes to modify a product so as to make it 
conform to the requirements of the solicitation, it shall: (1) include 
in its offer a clear description of such proposed modifications; and (2) 
clearly mark any descriptive material to show the proposed 
modifications.
    (e) Modifications to make a product conform to a brand name product 
referenced in the solicitation and proposed after the time for receipt 
of offers, will not be considered.

(End of provision)
[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



1252.211-71  Index for specifications.

    As prescribed in (TAR) 48 CFR 1210.011, insert the following clause:

                   Index for Specifications (Oct 1994)

    If an index or table of contents is furnished in connection with 
specifications, it is understood that such index or table of contents is 
for convenience only. Its accuracy and

[[Page 556]]

completeness is not guaranteed, and it is not to be considered as part 
of the specification. In case of discrepancy between the index or table 
of contents and the specifications, the specifications shall govern.

                             (End of clause)

[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



1252.213-90  Evaluation factor for Coast Guard performance of bar coding requirement. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1213.107-90, insert 
the following provision:

Evaluation Factor for Coast Guard Performance of Bar Coding Requirement 
                               (Oct 1994)

    If a small business cannot provide the bar coding requirement, as 
indicated elsewhere in the schedule, the contracting officer will apply 
the following formula to the quoted amounts:
    (a) Unit price quoted by small business $________
    (b) Add unit cost to the USCG to provide bar coding $________
    (c) Adjusted unit price (add lines a. and b.) $________
    The line (c) amount will become the amount the contracting officer 
considered when determining the lowest quoted amount.

(End of provision)



1252.215-70  Key personnel and/or facilities.

    As prescribed in (TAR) 48 CFR 1215.106, insert the following clause:

               Key Personnel and/or Facilities (Oct 1994)

    (a) The personnel and/or facilities as specified in paragraph (c) 
are considered essential to the work being performed hereunder and may, 
with the consent of the contracting parties, be changed from time to 
time during the course of the contract by adding or deleting personnel 
and/or facilities, as appropriate.
    (b) Prior to removing, replacing, or diverting any of the specified 
individuals or facilities, the Contractor shall notify, in writing, and 
receive consent from, the Contracting Officer reasonably in advance of 
the action and shall submit justification (including proposed 
substitutions) in sufficient detail to permit evaluation of the impact 
on this contract.
    (c) No diversion shall be made by the Contractor without the written 
consent of the Contracting Officer. The Contracting Officer may ratify, 
in writing, the change and such ratification shall constitute the 
consent of the Contracting Officer required by this clause.
    The Key Personnel and/or Facilities under this Contract:
(Specify key personnel and/or facilities)

                             (End of clause)



1252.216-70  Evaluation of offers subject to an economic price adjustment clause.

    As prescribed in (TAR) 48 CFR 1216.203-470, insert the following 
provision:

Evaluation of Offers Subject to an Economic Price Adjustment Clause (Oct 
                                  1994)

    Offers shall be evaluated without an amount for an economic price 
adjustment being added. Offers will be rejected which: (1) Increase the 
ceiling stipulated; (2) limit the downward adjustment; or (3) delete the 
economic price adjustment clause. If the offer stipulates a ceiling 
lower than that included in the solicitation, the lower ceiling will be 
incorporated into any resulting contract.

                           (End of provision)



1252.216-71  Determination of award fee.

    As prescribed in (TAR) 48 CFR 1216.405(a), insert the following 
clause:

                  Determination of Award Fee (Oct 1994)

    (a) The Government shall, at the conclusion of each specified 
evaluation period(s), evaluate the contractor's performance for a 
determination of award fee earned. The contractor agrees that the 
determination as to the amount of the award fee earned will be made by 
the Government Fee Determination Official (FDO) and such determination 
is binding on both parties and shall not be subject to appeal under the 
``Disputes'' clause or to any board or court.
    (b) It is agreed that the evaluation of contractor performance shall 
be in accordance with a Performance Evaluation Plan and that the 
contractor shall be promptly advised in writing of the determination and 
reasons why the award fee was or was not earned. It is further agreed 
that the contractor may submit a self-evaluation of performance of each 
period under consideration. While it is recognized that the basis for 
the determination of the fee shall be the evaluation by the Government, 
any self-evaluation which is received within ______ (insert number) days 
after the end of the period being evaluated may be given such 
consideration, if any, as the FDO shall find appropriate.
    (c) The FDO may specify in any fee determination that fee not earned 
during the period evaluated may be accumulated and be

[[Page 557]]

available for allocation to one or more subsequent periods. In that 
event, the distribution of award fee shall be adjusted to reflect such 
allocations.

                             (End of clause)



1252.216-72  Performance evaluation plan.

    As prescribed in (TAR) 48 CFR 1216.405(b), insert the following 
clause:

                 Performance Evaluation Plan (Oct 1994)

    (a) A Performance Evaluation Plan shall be unilaterally established 
by the Government based on the criteria stated in the contract and used 
for the determination of award fee. This plan shall include the criteria 
used to evaluate each area and the percentage of award fee (if any) 
available for each area. A copy of the plan shall be provided to the 
contractor ______ (insert number) calendar days prior to the start of 
the first evaluation period.
    (b) The criteria contained within the Performance Evaluation Plan 
may relate to: (1) Technical (including schedule) requirements if 
appropriate; (2) Management; and (3) Cost.
    (c) The Performance Evaluation Plan may, consistent with the 
contract, be revised unilaterally by the Government at any time during 
the period of performance. Notification of such changes shall be 
provided to the contractor ______ (insert number) calendar days prior to 
the start of the evaluation period to which the change will apply.

                             (End of clause)



1252.216-73  Distribution of award fee.

    As prescribed in (TAR) 48 CFR 1216.405(c), insert the following 
clause:

                  Distribution of Award Fee (Oct 1994)

    (a) The total amount of award fee available under this contract is 
assigned according to the following evaluation periods and amounts:
    Evaluation Period:
    Available Award Fee:
    (insert appropriate information)
    (b) Payment of the base fee and award fee shall be made, provided 
that after payment of 85 percent of the base fee and potential award 
fee, the Government may withhold further payment of the base fee and 
award fee until a reserve is set aside in an amount that the Government 
considers necessary to protect its interest. This reserve shall not 
exceed 15 percent of the total base fee and potential award fee or 
$100,000, whichever is less.
    (c) In the event of contract termination, either in whole or in 
part, the amount of award fee available shall represent a prorata 
distribution associated with evaluation period activities or events as 
determined by the Government.
    (d) The Government will promptly make payment of any award fee upon 
the submission by the contractor to the contracting officer's authorized 
representative, of a public voucher or invoice in the amount of the 
total fee earned for the period evaluated. Payment may be made without 
using a contract modification.

                             (End of clause)



1252.216-74  Settlement of letter contract.

    As prescribed in (TAR) 48 CFR 1216.603-4, insert the following 
clause:

                Settlement of Letter Contract (Oct 1994)

    (a) This contract constitutes the definitive contract contemplated 
by issuance of letter contract ______ (insert number) dated ______ 
(insert effective date). It supersedes the letter contract and its 
modification number(s) ______ (insert number(s)) and, to the extent of 
any inconsistencies, governs. (b) The cost(s) and fee(s), or price(s), 
established in this definitive contract represents full and complete 
settlement of letter contract ______ (insert number and modification 
number(s) ______ (insert number(s)). Payment of the agreed upon fee or 
profit withheld pending definitization of the letter contract, may 
commence immediately at the rate and times stated within this contract.

                             (End of clause)



1252.217-71  Delivery and shifting of vessel.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

               Delivery and Shifting of Vessel (Oct 1994)

    The Government shall deliver the vessel to the Contractor at his 
place of business. Upon completion of the work, the Government shall 
accept delivery of the vessel at the Contractor's place of business. The 
Contractor shall provide, at no additional charge, upon 24 hours' 
advance notice, a tug or tugs and docking pilot, acceptable to the 
Contracting Officer, to assist in handling the vessel between (to and 
from) the Contractor's plant and the nearest point in a waterway 
regularly navigated by vessels of equal or greater draft and length. 
While the vessel is in the hands of the Contractor, any necessary 
towage, cartage, or other transportation between ship and shop or 
elsewhere, which may be incident to the work herein specified, shall be 
furnished by the Contractor without additional charge to the Government.

[[Page 558]]

                             (End of clause)



1252.217-72  Performance.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

                         Performance (Oct 1994)

    (a) Upon the award of the contract, the Contractor shall promptly 
start the work specified and shall diligently prosecute the work to 
completion. The Contractor shall not start work until the contract has 
been awarded except in the case of emergency work ordered by the 
Contracting Officer in writing.
    (b) The Government shall deliver the vessel described in the 
contract at the time and location specified in the contract. Upon 
completion of the work, the Government shall accept delivery of the 
vessel at the time and location specified in the contract.
    (c) The Contractor shall without charge,--
    (1) Make available to personnel of the vessel while in dry dock or 
on a marine railway, sanitary lavatory and similar facilities at the 
plant acceptable to the Contracting Officer;
    (2) Supply and maintain suitable brows and gangways from the pier, 
dry dock, or marine railway to the vessel;
    (3) Treat salvage, scrap or other ship's material of the Government 
resulting from performance of the work as items of Government-furnished 
property, in accordance with the Government Property (Fixed Price 
Contracts) clause;
    (4) Perform, or pay the cost of, any repair, reconditioning or 
replacement made necessary as the result of the use by the Contractor of 
any of the vessel's machinery, equipment or fittings, including, but not 
limited to, winches, pumps, rigging, or pipe lines; and
    (5) Furnish suitable offices, office equipment and telephones at or 
near the site of the work for the Government's use.
    (d) The contract will state whether dock and sea trials are required 
to determine whether or not the Contractor has satisfactorily performed 
the work.
    (1) If dock and sea trials are required, the vessel shall be under 
the control of the vessel's commander and crew.
    (2) The Contractor shall not conduct dock and sea trials not 
specified in the contract without advance approval of the Contracting 
Officer. Dock and sea trials not specified in the contract shall be at 
the Contractor's expense and risk.
    (3) The Contractor shall provide and install all fittings and 
appliances necessary for dock and sea trials. The Contractor shall be 
responsible for care, installation, and removal of instruments and 
apparatus furnished by the Government for use in the trials.

                             (End of clause)



1252.217-73  Inspection and manner of doing work.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

             Inspection and Manner of Doing Work (Oct 1994)

    (a) The Contractor shall perform work in accordance with the 
contract, any drawings and specifications made a part of the job order, 
and any change or modification issued under the Changes clause.
    (b)(1) Except as provided in paragraph (b)(2) of this clause, and 
unless otherwise specifically provided in the contract, all operational 
practices of the Contractor and all workmanship, material, equipment, 
and articles used in the performance of work under this contract shall 
be in accordance with the best commercial marine practices and the rules 
and requirements of the American Bureau of Shipping, the U.S. Coast 
Guard, and the Institute of Electrical and Electronic Engineers, in 
effect at the time of Contractor's submission of offer.
    (2) When Navy specifications are specified in the contract, the 
Contractor shall follow Navy standards of material and workmanship. The 
solicitation shall prescribe the Navy standard whenever applicable.
    (c) The Government may inspect and test all material and workmanship 
at any time during the Contractor's performance of the work.
    (1) If, prior to delivery, the Government finds any material or 
workmanship is defective or not in accordance with the contract, in 
addition to its rights under the Guarantee clause, the Government may 
reject the defective or nonconforming material or workmanship and 
require the Contractor to correct or replace it at the Contractor's 
expense.
    (2) If the Contractor fails to proceed promptly with the replacement 
or correction of the material or workmanship, the Government may replace 
or correct the defective or nonconforming material or workmanship and 
charge the Contractor the excess costs incurred.
    (3) As specified in the contract, the Contractor shall provide and 
maintain an inspection system acceptable to the Government.
    (4) The Contractor shall maintain complete records of all inspection 
work and shall make them available to the Government during performance 
of the contract and for 90 days after the completion of all work 
required.
    (d) The Contractor shall not permit any welder to work on a vessel 
unless the welder is, at the time of the work, qualified to the 
standards established by the U.S. Coast

[[Page 559]]

Guard, American Bureau of Shipping, or Department of the Navy for the 
type of welding being performed. Qualifications of a welder shall be as 
specified in the contract.
    (e) The Contractor shall--
    (1) Exercise reasonable care to protect the vessel from fire;
    (2) Maintain a reasonable system of inspection over activities 
taking place in the vicinity of the vessel's magazines, fuel oil tanks, 
or storerooms containing flammable materials.
    (3) Maintain a reasonable number of hose lines ready for immediate 
use on the vessel at all times while the vessel is berthed alongside the 
Contractor's pier or in dry dock or on a marine railway;
    (4) Unless otherwise provided in the contract, provide sufficient 
security patrols to reasonably maintain a fire watch for protection of 
the vessel when it is in the Contractor's custody;
    (5) To the extent necessary, clean, wash, and steam out or otherwise 
make safe, all tanks under alteration or repair.
    (6) Furnish the Contracting Officer a ``gas-free'' or ``safe-for-
hotwork'' certificate before any hot work is done on a tank;
    (7) Treat the contents of any tank as Government property in 
accordance with the Government Property (Fixed-Price Contracts) clause; 
and
    (8) Dispose of the contents of any tank only at the direction, or 
with the concurrence, of the Contracting Officer.
    (f) Except as otherwise provided in the contract, when the vessel is 
in the custody of the Contractor or in dry dock or on a marine railway 
and the temperature is expected to go as low as 35 Fahrenheit, the 
Contractor shall take all necessary steps to--
    (1) Keep all hose pipe lines, fixtures, traps, tanks, and other 
receptacles on the vessel from freezing; and
    (2) Protect the stern tube and propeller hubs from frost damage.
    (g) The Contractor shall, whenever practicable--
    (1) Perform the required work in a manner that will not interfere 
with the berthing and messing of Government personnel attached to the 
vessel; and
    (2) Provide Government personnel attached to the vessel access to 
the vessel at all times.
    (h) Government personnel attached to the vessel shall not interfere 
with the Contractor's work or workers.
    (i)(1) The Government does not guarantee the correctness of the 
dimensions, sizes, and shapes set forth in any contract, sketches, 
drawings, plans, or specifications prepared or furnished by the 
Government, unless the contract requires that the Contractor perform the 
work prior to any opportunity to inspect.
    (2) Except as stated in paragraph (i)(1) of this clause, and other 
than those parts furnished by the Government, and the Contractor shall 
be responsible for the correctness of the dimensions, sizes, and shapes 
of parts furnished under this agreement.
    (j) The Contractor shall at all times keep the site of the work on 
the vessel free from accumulation of waste material or rubbish caused by 
its employees or the work. At the completion of the work, unless the 
contract specifies otherwise, the Contractor shall remove all rubbish 
from the site of the work and leave the immediate vicinity of the work 
area ``broom clean.''

                             (End of clause)



1252.217-74  Subcontracts.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

                         Subcontracts (Oct 1994)

    (a) Nothing contained in the contract shall be construed as creating 
any contractual relationship between any subcontractor and the 
Government. The divisions or sections of the specifications are not 
intended to control the Contractor in dividing the work among 
subcontractors or to limit the work performed by any trade.
    (b) The Contractor shall be responsible to the Government for acts 
and omissions of its own employees, and of subcontractors and their 
employees. The Contractor shall also be responsible for the coordination 
of the work of the trades, subcontractors, and material men.
    (c) The Contractor shall, without additional expense to the 
Government, employ specialty subcontractors where required by the 
specifications.
    (d) The Government or its representatives will not undertake to 
settle any differences between the Contractor and its subcontractors, or 
between subcontractors.

                             (End of clause)



1252.217-75  Lay days.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

                           Lay Days (Oct 1994)

    (a) Lay day time will be paid by the Government at the Contractor's 
stipulated bid price for this item of the contract when the vessel 
remains on the dry dock or marine railway as a result of any change that 
involves work in addition to that required under the basic contract.
    (b) No lay day time shall be paid until all items of the basic 
contract for which a price was established by the Contractor and for 
which docking of the vessel was required

[[Page 560]]

have been satisfactorily completed and accepted.
    (c) Days of hauling out and floating, whatever the hour, shall not 
be paid as lay day time, and days when no work is performed by the 
Contractor shall not be paid as lay day time.
    (d) Payment of lay day time shall constitute complete compensation 
for all costs, direct and indirect, to reimburse the Contractor for use 
of dry dock or marine railway.

                             (End of clause)



1252.217-76  Liability and insurance.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

                   Liability and Insurance (Oct 1994)

    (a) The Contractor shall exercise its best efforts to prevent 
accidents, injury, or damage to all employees, persons, and property, in 
and about the work, and to the vessel or part of the vessel upon which 
work is done.
    (b) Loss or damage to the vessel, materials, or equipment. (1) 
Unless otherwise directed or approved in writing by the Contracting 
Officer, the Contractor shall not carry insurance against any form of 
loss or damage to the vessel(s) or to the materials or equipment to 
which the Government has title or which have been furnished by the 
Government for installation by the Contractor. The Government assumes 
the risks of loss of and damage to that property.
    (2) The Government does not assume any risk with respect to loss or 
damage compensated for by insurance or otherwise or resulting from risks 
with respect to which the Contractor has failed to maintain insurance, 
if available, as required or approved by the Contracting Officer.
    (3) The Government does not assume risk of and will not pay for any 
costs of the following:
    (i) Inspection, repair, replacement, or renewal of any defects in 
the vessel(s) or material and equipment due to--
    (A) Defective workmanship performed by the Contractor or its 
subcontractors;
    (B) Defective materials or equipment furnished by the Contractor or 
its subcontractors; or
    (C) Workmanship, materials, or equipment which do not conform to the 
requirements of the contract, whether or not the defect is latent or 
whether or not the nonconformance is the result of negligence.
    (ii) Loss, damage, liability, or expense caused by, resulting from, 
or incurred as a consequence of any delay or disruption, willful 
misconduct or lack of good faith by the Contractor or any of its 
representatives that have supervision or direction of--
    (A) All or substantially all of the Contractor's business; or
    (B) All or substantially all of the Contractor's operation at any 
one plant.
    (4) As to any risk that is assumed by the Government, the Government 
shall be subrogated to any claim, demand or cause of action against 
third parties that exists in favor of the Contractor. If required by the 
Contracting Officer, the Contractor shall execute a formal assignment or 
transfer of the claim, demand, or cause of action.
    (5) No party other than the Contractor shall have any right to 
proceed directly against the Government or join the Government as a 
codefendant in any action.
    (6) Notwithstanding the foregoing, the Contractor shall bear the 
first $5,000 of loss or damage from each occurrence or incident, the 
risk of which the Government would have assumed under the provision of 
this paragraph (b).
    (c) Indemnification. The Contractor indemnifies the Government and 
the vessel and its owners against all claims, demands, or causes of 
action to which the Government, the vessel or its owner(s) might be 
subject as a result of damage or injury (including death) to the 
property or person of anyone other than the Government or its employees, 
or the vessel or its owner, arising in whole or in part from the 
negligence or other wrongful act of the Contractor, or its agents or 
employees, or any subcontractor, or its agents or employees.
    (1) The Contractor's obligation to indemnify under this paragraph 
shall not exceed the sum of $300,000 as a consequence of any single 
occurrence with respect to any one vessel.
    (2) The indemnity includes, without limitation, suits, actions, 
claims, costs, or demands of any kind, resulting from death, personal 
injury, or property damage occurring during the period of performance of 
work on the vessel or within 90 days after redelivery of the vessel. For 
any claim, etc., made after 90 days, the rights of the parties shall be 
as determined by other provisions of this contract and by law. The 
indemnity does apply to death occurring after 90 days where the injury 
was received during the period covered by the indemnity.
    (d) Insurance. (1) The Contractor shall, at its own expense, obtain 
and maintain the following insurance--
    (i) Casualty, accident, and liability insurance, as approved by the 
Contracting Officer, insuring the performance of its obligations under 
paragraph (c) of this clause.
    (ii) Workers Compensation Insurance (or its equivalent) covering the 
employees engaged on the work.
    (2) The Contractor shall ensure that all subcontractors engaged on 
the work obtain and maintain the insurance required in paragraph (d)(1) 
of this clause.

[[Page 561]]

    (3) Upon request of the Contracting Officer, the Contractor shall 
provide evidence of the insurance required by paragraph (d) of this 
clause.
    (e) The Contractor shall not make any allowance in the contract 
price for the inclusion of any premium expense or charge for any reserve 
made on account of self-insurance for coverage against any risk assumed 
by the Government under this clause.
    (f) The Contractor shall give the Contracting Officer written notice 
as soon as practicable after the occurrence of a loss or damage for 
which the Government has assumed the risk.
    (1) The notice shall contain full details of the loss or damage.
    (2) If a claim or suit is later filed against the Contractor as a 
result of the event, the Contractor shall immediately deliver to the 
Government every demand, notice, summons, or other process received by 
the Contractor or its employees or representatives.
    (3) The Contractor shall cooperate with the Government and, upon 
request, shall assist in effecting settlements, securing and giving 
evidence, obtaining the attendance of witnesses, and in the conduct of 
suits. The Government shall reimburse the Contractor for expenses 
incurred in this effort, other than the cost of maintaining the 
Contractor's usual organization.
    (4) The Contractor shall not, except at its own expense, voluntarily 
make any payments, assume any obligation, or incur any expense other 
than what would be imperative for the protection of the vessel(s) at the 
time of the event.
    (g) In the event of loss of or damage to any vessel(s), material, or 
equipment which may result in a claim against the Government under the 
insurance provisions of this contract, the Contractor shall promptly 
notify the Contracting Officer of the loss or damage. The Contracting 
Officer may, without prejudice to any right of the Government, either--
    (1) Order the Contractor to proceed with replacement or repair, in 
which event the Contractor shall effect the replacement or repair;
    (i) The Contractor shall submit to the Contracting Officer a request 
for reimbursement of the cost of the replacement or repair together with 
whatever supporting documentation the Contracting Officer may reasonably 
require, and shall identify the request as being submitted under the 
Insurance clause of this contract.
    (ii) If the Government determines that the risk of the loss or 
damage is within the scope of the risks assumed by the Government under 
this clause, the Government will reimburse the Contractor for the 
reasonable allowable cost of the replacement or repair, plus a 
reasonable profit (if the work or replacement or repair was performed by 
the Contractor) less the deductible amount specified in paragraph (b) of 
this clause.
    (iii) Payments by the Government to the Contractor under this clause 
are outside the scope of and shall not affect the pricing structure of 
the contract, and are additional to the compensation otherwise payable 
to the Contractor under this contract; or
    (2) Decide that the loss or damage shall not be replaced or repaired 
and in that event, the Contracting Officer shall--
    (i) Modify the contract appropriately, consistent with the reduced 
requirements reflected by the unreplaced or unrepaired loss or damage; 
or
    (ii) Terminate the repair of any part or all of the vessel(s) under 
the Termination for Convenience of the Government clause of this 
contract.

                             (End of clause)



1252.217-77  Title.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

                            Title (Oct 1994)

    (a) Unless otherwise provided, title to all materials and equipment 
to be incorporated in a vessel in the performance of this contract shall 
vest in the Government upon delivery at the location specified for the 
performance of the work.
    (b) Upon completion of the contract, or with the approval of the 
Contracting Officer during performance of the contract, all Contractor-
furnished materials and equipment not incorporated in, or placed on, any 
vessel, shall become the property of the Contractor, unless the 
Government has reimbursed the Contractor for the cost of the materials 
and equipments.
    (c) The vessel, its equipment, movable stores, cargo, or other 
ship's materials shall not be considered Government-furnished property.

                             (End of clause)



1252.217-78  Discharge of liens.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

                      Discharge of Liens (Oct 1994)

    (a) The Contractor shall immediately discharge or cause to be 
discharged, any lien or right in rem of any kind, other than in favor of 
the Government, that exists or arises in connection with work done or 
materials furnished under this contract.
    (b) If any such lien or right in rem is not immediately discharged, 
the Government, at the expense of the Contractor, may discharge, or 
cause to be discharged, the lien or right.

[[Page 562]]

                             (End of clause)



1252.217-79  Delays.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

                            Delays (Oct 1994)

    When during the performance of this contract the Contractor is 
required to delay work on a vessel temporarily, due to orders or actions 
of the Government respecting stoppage of work to permit shifting the 
vessel, stoppage of hot work to permit bunkering, stoppage of work due 
to embarking or debarking passengers and loading or discharging cargo, 
and the Contractor is not given sufficient advance notice or is 
otherwise unable to avoid incurring additional costs on account thereof, 
an equitable adjustment shall be made in the price of the contract 
pursuant to the ``Changes'' clause.

                             (End of clause)



1252.217-80  Department of Labor safety and health regulations for ship repairing.

    As prescribed at 1217.7000 (a) and (b), insert the following clause:

 Department of Labor Safety and Health Regulations for Ship Repair (Oct 
                                  1994)

    Nothing contained in this contract shall relieve the Contractor of 
any obligations it may have to comply with--
    (a) The Occupational Safety and Health Act of 1970 (29 U.S.C. 651, 
et seq.);
    (b) The Safety and Health Regulations for Ship Repairing (29 CAR 
part 1915); or
    (c) Any other applicable Federal, State, and local laws, codes, 
ordinances, and regulations.

                             (End of clause)



1252.217-81  Guarantee.

    As prescribed at 1217.7000(c), insert the following clause:

                          Guarantee (Oct 1994)

    (a) In the event any work performed or materials furnished by the 
contractor prove defective or deficient within 60 days from the date of 
redelivery of the vessel(s), the Contractor, as directed by the 
Contracting Officer and at its own expense, shall correct and repair the 
deficiency to the satisfaction of the Contracting Officer.
    (b) If the Contractor or any subcontractor has a guarantee for work 
performed or materials furnished that exceeds the 60 day period, the 
Government shall be entitled to rely upon the longer guarantee until its 
expiration.
    (c) With respect to any individual work item identified as 
incomplete at the time of redelivery of the vessel(s), the guarantee 
period shall run from the date the item is completed.
    (d) If practicable, the Government shall give the Contractor an 
opportunity to correct the deficiency.
    (1) If the Contracting Officer determines it is not practicable or 
is otherwise not advisable to return the vessel(s) to the Contractor, or 
the Contractor fails to proceed with the repairs promptly, the 
Contracting Officer may direct that the repairs be performed elsewhere, 
at the Contractor's expense.
    (2) If correction and repairs are performed by other than the 
Contractor, the Contracting Officer may discharge the Contractor's 
liability by making an equitable deduction in the price of the contract.
    (e) The Contractor's liability shall extend for an additional 90 day 
guarantee period on those defects or deficiencies that the Contractor 
corrected.
    (f) At the option of the Contracting officer, defects and 
deficiencies may be left uncorrected. In that event, the Contractor and 
Contracting Officer shall negotiate an equitable reduction in the 
contract price. Failure to agree upon an equitable reduction shall 
constitute a dispute under the Disputes clause of this contract.

                             (End of clause)

[59 FR 40288, Aug. 8, 1994, as amended at 60 FR 55802, Nov. 3, 1995]



1252.219-70  Small business and small disadvantaged business subcontracting reporting.

    As prescribed in (TAR) 48 CFR 1219.708-70, insert the following 
clause:

Small Business and Small Disadvantaged Business Subcontracting Reporting 
                               (Oct 1994)

    (a) The Contractor shall submit the Summary Subcontract Report 
(Standard Form 295 (SF-295)) to the Department of Transportation, Office 
of the Secretary, Office of Small and Disadvantaged Business Utilization 
(S-42), 400 7th St., SW, Washington, DC, 20590.
    (b) The Contractor shall include this clause in all subcontracts 
that include the clause at (FAR) 48 CFR 52.219-9.

                             (End of clause)

[59 FR 40288, Aug 8, 1994, as amended at 62 FR 26420, May 14, 1997]

[[Page 563]]



1252.220-90  Local hire. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1220.9001, insert the 
following clause:

                          Local Hire (Oct 1994)

    The Contractor shall employ, for the purpose of performing this 
contract in whole or in part in a State that has an unemployment rate in 
excess of the national average rate of unemployment (as defined by the 
Secretary of Labor), individuals who are local residents and who, in the 
case of any craft or trade, possess or would be able to acquire promptly 
the necessary skills. Local Resident means a resident or an individual 
who commutes daily to that State.

                             (End of clause)



1252.222-70  Strikes or picketing affecting timely completion of the contract work.

    As prescribed in (TAR) 48 CFR 1222.101-71(a), insert the following 
clause:

 Strikes or Picketing Affecting Timely Completion of the Contract Work 
                               (Oct 1994)

    Notwithstanding any other provision hereof, the Contractor is 
responsible for delays arising out of labor disputes, including but not 
limited to strikes, if such strikes are reasonably avoidable. A delay 
caused by a strike or by picketing which constitutes an unfair labor 
practice is not excusable unless the Contractor takes all reasonable and 
appropriate action to end such a strike or picketing, such as the filing 
of a charge with the National Labor Relations Board, the use of other 
available Government procedures, and the use of private boards or 
organizations for the settlement of disputes.

                             (End of clause)



1252.222-71  Strikes or picketing affecting access to a DOT facility.

    As prescribed in (TAR) 48 CFR 1222.101-71(b), insert the following 
clause:

   Strikes or Picketing Affecting Access to a DOT Facility (Oct 1994)

    If the Contracting Officer notifies the Contractor in writing that a 
strike or picketing: (a) is directed at the Contractor or subcontractor 
or any employee of either; and (b) impedes or threatens to impede access 
by any person to a DOT facility where the site of the work is located, 
the Contractor shall take all appropriate action to end such strike or 
picketing, including, if necessary, the filing of a charge of unfair 
labor practice with the National Labor Relations Board or the use of 
other available judicial or administrative remedies.

                             (End of clause)



1252.223-70  Removal or disposal of hazardous substances--applicable licenses and permits.

    As prescribed in (TAR) 48 CFR 1223.303, insert the following clause:

  Removal or Disposal of Hazardous Substances--Applicable Licenses and 
                           Permits (Oct 1994)

    The Contractor certifies that it has ______ does not have ______ all 
licenses and permits required by Federal, state, and local laws to 
perform hazardous substance(s) removal or disposal services. If the 
Contractor does not currently possess these documents, it hereby 
certifies that it will obtain all requisite licenses and permits within 
______ days after date of award. The Contractor shall provide evidence 
of said documents to the Contracting Officer or designated Government 
representative prior to commencement of work under the contract.

                             (End of clause)



1252.223-71  Accident and fire reporting.

    As prescribed in (TAR) 48 CFR 1223.7000(a), insert the following 
clause:

                 Accident and Fire Reporting (Oct 1994)

    (a) The Contractor shall report to the Contracting Officer any 
accident or fire occurring at the site of the work which causes:
    (1) A fatality or as much as one lost workday on the part of any 
employee of the Contractor or subcontractor at any tier;
    (2) Damage of $1,000 or more to Federal property, either real or 
personal;
    (3) Damage of $1,000 or more to Contractor or subcontractor owned or 
leased motor vehicles or mobile equipment; or
    (4) Damage for which a contract time extension may be requested.
    (b) Accident and fire reports required by paragraph (a) of this 
section shall be accomplished by the following means:
    (1) Accidents or fires resulting in a death, hospitalization of five 
or more persons, or destruction of Federal property (either real or 
personal), the total value of which is estimated at $100,000 or more, 
shall be reported immediately by telephone to the Contracting Officer or 
his/her authorized representative and shall be confirmed by telegram or 
facsimile transmission within 24 hours to the Contracting Officer. Such 
telegram or facsimile transmission shall state all known

[[Page 564]]

facts as to extent of injury and damage and as to cause of the accident 
or fire.
    (2) Other accident and fire reports required by paragraph (a) of 
this section may be reported by the Contractor using a state, private 
insurance carrier, or Contractor accident report form which provides for 
the statement of:
    (i) The extent of injury; and
    (ii) The damage and cause of the accident or fire.
    Such report shall be mailed or otherwise delivered to the 
Contracting Officer within 48 hours of the occurrence of the accident or 
fire.
    (c) The Contractor shall assure compliance by subcontractors at all 
tiers with the requirements of this clause.

                             (End of clause)



1252.223-72  Protection of human subjects.

    As prescribed in (TAR) 48 CFR 1223.7000(b), insert the following 
clause:

                 Protection of Human Subjects (Oct 1994)

    The Contractor shall comply with the National Highway Traffic Safety 
Administration (NHTSA) principles and procedures (in accordance with 
NHTSA Order 700-1, 700-3, and 700-4) for the protection of human 
subjects participating in activities supported directly or indirectly by 
contracts from DOT. A copy of the applicable NHTSA orders shall be 
provided to offerors and/or contractors upon request. In fulfillment of 
its assurance:
    (a) A committee competent to review projects and activities that 
involve human subjects shall be established and maintained by the 
Contractor.
    (b) The committee shall be assigned responsibility to determine for 
each activity planned and conducted that:
    (1) The rights and welfare of subjects are adequately protected;
    (2) The risks to subjects are outweighed by potential benefits; and
    (3) The informed consent of subjects shall be obtained by methods 
that are adequate and appropriate.
    (c) Committee reviews are to be conducted with objectivity and in a 
manner to ensure the exercise of independent judgment of the members. 
Members shall be excluded from review of projects or activities in which 
they have an active role or a conflict of interests.
    (d) Continuing constructive communication between the committee and 
the project directors must be maintained as a means of safeguarding the 
rights and welfare of subjects.
    (e) Facilities and professional attention required for subjects who 
may suffer physical, psychological, or other injury as a result of 
participating in an activity shall be provided.
    (f) The committee shall maintain records of committee review of 
applications and active projects, of documentation of informed consent, 
and of other documentation that may pertain to the selection, 
participation, and protection of subjects. Detailed records shall be 
maintained of circumstances of any review that adversely affects the 
rights or welfare of the individual subjects. Such materials shall be 
made available to DOT upon request.
    (g) The retention period of such records and materials shall be as 
specified at (FAR) 48 CFR 4.703.
    (h) Periodic reviews shall be conducted by the Contractor to assure, 
through appropriate administrative overview, that the practices and 
procedures designed for the protection of the rights and welfare of 
subjects are being effectively applied.

    (Note: If the Contractor has a Department of Health and Human 
Services approved Institutional Review Board (IRB) which can 
appropriately review this contract in accordance with the technical 
requirements and NHTSA Orders 700-1, 700-3, and 700-4, that IRB will be 
considered acceptable for the purposes of this contract.

                             (End of clause)



1252.225-90  Buy American Certificate--steel and manufactured products. (FAA)

    As prescribed in 1225.9005(a), insert the following provision in 
solicitations:

  Buy American Certificate--Steel and Manufactured Products (Oct 1994)

    (a) By submitting a bid/proposal under this solicitation, except for 
those items listed by the offeror in paragraph (b), the offeror 
certifies that steel and manufactured products to be used in the project 
are produced in the United States and that components of unknown origin 
are considered to have been produced or manufactured outside the United 
States.
    (b) This certification is required in implementation of Section 9129 
of the Aviation Safety and Capacity Expansion Act of 1990, (Subtitle B 
of Title IX of Pub. L. 101-508, the Omnibus Budget Reconciliation Act of 
1990).

                                                                        
------------------------------------------------------------------------
              PRODUCT                         COUNTRY OF ORIGIN         
------------------------------------------------------------------------
                                     ...................................
                                                                        
                                     ...................................
                                                                        
                                     ...................................
                                                                        
                                     ...................................

[[Page 565]]

                                                                        
------------------------------------------------------------------------

                           (End of provision)



1252.225-91  Buy American--steel and manufactured products. (FAA)

    As prescribed in 1225.9005(b), insert the following clause in 
solicitations and contracts:

        Buy American--Steel and Manufactured Products (Oct 1994)

    (a) Section 9129 of the Aviation Safety and Capacity Expansion Act 
of 1990 (Subtitle B of Title IX of Pub. L. 101-508, the Omnibus Budget 
Reconciliation Act of 1990) requires the use of steel and manufactured 
products produced in the United States when a project such as that 
covered by this contract receives funding.
    (b) The Contractor shall deliver only steel and manufactured 
products produced in the United States. This requirement shall not apply 
where the Secretary or his or her designee has found--
    (1) that its application would be inconsistent with the public 
interest;
    (2) that such materials are not produced in the United States in 
sufficient and reasonably available quantities and of a satisfactory 
quality;
    (3) in the case of the procurement of facilities and equipment under 
the Airport and Airway Improvement Act of 1982, (i) the cost of 
components and subcomponents which are produced in the United States is 
more than 60 percent of the cost of all components to be delivered under 
this contract, and (ii) final assembly of the facility or equipment to 
be delivered under this contract has taken place in the United States; 
or
    (4) that inclusion of domestic material will increase the cost of 
the overall contract by more than 25 percent.
    (c) In calculating components' costs, labor costs involved in final 
assembly shall not be included in the calculation.
    (d) This clause takes precedence over the provisions of the (FAR) 48 
CFR 52.225-3, Buy American--Supplies, and the (FAR) 48 CFR clause 
52.225-5, Buy American--Construction Materials, in respect to their 
applicability to steel and manufactured products.

                             (End of clause)



1252.228-70  Loss of or damage to leased aircraft.

    As prescribed in (TAR) 48 CFR 1228.306-70 (a) and (b), insert the 
following clause:

             Loss of or Damage to Leased Aircraft (Oct 1994)

    (a) The Government assumes all risk of loss of, or damage (except 
normal wear and tear) to, the leased aircraft during the term of this 
lease while the aircraft is in the possession of the Government.
    (b) In the event of damage to the aircraft, the Government, at its 
option, shall make the necessary repairs with its own facilities or by 
contract, or pay the Contractor the reasonable cost of repair of the 
aircraft.
    (c) In the event the aircraft is lost or damaged beyond repair, the 
Government shall pay the Contractor a sum equal to the fair market value 
of the aircraft at the time of such loss or damage, which value may be 
specifically agreed to in clause 1252.228-71, ``Fair Market Value of 
Aircraft,'' less the salvage value of the aircraft. However, the 
Government may retain the damaged aircraft or dispose of it as it 
wishes. In that event, the Contractor will be paid the fair market value 
of the aircraft as stated in the clause.
    (d) The Contractor certifies that the contract price does not 
include any cost attributable to hull insurance or to any reserve fund 
it has established to protect its interest in the aircraft. If, in the 
event of loss or damage to the leased aircraft, the Contractor receives 
compensation for such loss or damage in any form from any source, the 
amount of such compensation shall be:
    (1) credited to the Government in determining the amount of the 
Government's liability; or
    (2) for an increment of value of the aircraft beyond the value for 
which the Government is responsible.
    (e) In the event of loss of or damage to the aircraft, the 
Government shall be subrogated to all rights of recovery by the 
Contractor against third parties for such loss or damage and the 
Contractor shall promptly assign such rights in writing to the 
Government.

                             (End of clause)



1252.228-71  Fair market value of aircraft.

    As prescribed in (TAR) 48 CFR 1228.306-70 (a) and (c), insert the 
following clause:

                Fair Market Value of Aircraft (Oct 1994)

    For purposes of the clause entitled ``Loss of or Damage to Leased 
Aircraft,'' it is agreed that the fair market value of the aircraft to 
be used in the performance of this contract shall be the lesser of the 
two values set out in paragraphs (a) and (b):
    (a) $____________; or
    (b) If the contractor has insured the same aircraft against loss or 
destruction in connection with other operations, the amount of such 
insurance coverage on the date of the loss or damage for which the 
Government may be responsible under this contract.

[[Page 566]]

                             (End of clause)



1228.228-72  Risk and indemnities.

    As prescribed in (TAR) 48 CFR 1228.306-70 (a) and (d), insert the 
following clause:

                     Risk and Indemnities (Oct 1994)

    The Contractor hereby agrees to indemnify and hold harmless the 
Government, its officers and employees from and against all claims, 
demands, damages, liabilities, losses, suits and judgments (including 
all costs and expenses incident thereto) which may be suffered by, 
accrue against, be charged to or recoverable from the Government, its 
officers and employees by reason of injury to or death of any person 
other than officers, agents, or employees of the Government or by reason 
of damage to property of others of whatsoever kind (other than the 
property of the Government, its officers, agents or employees) arising 
out of the operation of the aircraft. In the event the Contractor holds 
or obtains insurance in support of this covenant, a Certificate of 
Insurance shall be delivered to the Contracting Officer.

                             (End of clause)



1252.228-90  Notification of Miller Act payment bond protection. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1228.9000, insert the 
following clause:

      Notification of Miller Act Payment Bond Protection (Oct 1994)

    This notice clause shall be inserted by first tier subcontractors in 
all their subcontracts and shall contain the surety which has provided 
the payment bond under the prime contract.
    (a) The prime contract is subject to the Miller Act (40 U.S.C. 270), 
under which the prime contractor has obtained a payment bond. This 
payment bond may provide certain unpaid employees, suppliers, and 
subcontractors a right to sue the bonding surety under the Miller Act 
for amounts owed for work performed and materials delivery under the 
prime contract.
    (b) Persons believing that they have legal remedies under the Miller 
Act should consult their legal advisor regarding the proper steps to 
take to obtain these remedies. This notice clause does not provide any 
party any rights against the Federal Government, or create any 
relationship, contractual or otherwise, between the Federal Government 
and any private party.
    (c) The surety which has provided the payment bond under the prime 
contract is:

 _______________________________________________________________________
(Name)

 _______________________________________________________________________
(Street Address)

 _______________________________________________________________________
(City, State, Zip Code)

 _______________________________________________________________________
(Contact & Tel. No.)

                             (End of clause)



1252.231-70  Date of incurrence of costs.

    As prescribed in (TAR) 48 CFR 1231.205-32, insert the following 
clause:

                 Date of Incurrence of Costs (Oct 1994)

    The Contractor shall be entitled to reimbursement for costs incurred 
on or after ______ in an amount not to exceed $______ that, if incurred 
after this contract had been entered into, would have been reimbursable 
under this contract.

                             (End of clause)



1252.236-70  Special precautions for work at operating airports.

    As prescribed in (TAR) 48 CFR 1236.570, insert the following clause:

      Special Precautions for Work at Operating Airports (Oct 1994)

    (a) When work is to be performed at an operating airport, the 
Contractor must arrange its work schedule so as not to interfere with 
flight operations. Such operations will take precedence over 
construction convenience. Any operations of the Contractor which would 
otherwise interfere with or endanger the operations of aircraft shall be 
performed only at times and in the manner directed by the Contracting 
Officer. The Government will make every effort to reduce the disruption 
of the Contractor's operation.
    (b) Unless otherwise specified by local regulations, all areas in 
which construction operations are underway shall be marked by yellow 
flags during daylight hours and by red lights at other times. The red 
lights along the edge of the construction areas within the existing 
aprons shall be the electric type of not less than 100 watts intensity 
placed and supported as required. All other construction markings on 
roads and adjacent parking lots may be either electric or battery type 
lights. These lights and flags shall be placed so as to outline the 
construction areas and the distance between any two flags or lights 
shall not be greater than 25 feet. The Contractor shall provide adequate 
watch to maintain the lights in working condition at all times other 
than daylight hours. The hour of beginning and the hour of ending of 
daylight will be determined by the Contracting Officer.

[[Page 567]]

    (c) All equipment and material in the construction areas or when 
moved outside the construction area shall be marked with airport safety 
flags during the day and when directed by the Contracting Officer, with 
red obstruction lights at nights. All equipment operating on the apron, 
taxiway, runway, and intermediate areas after darkness hours shall have 
clearance lights in conformance with instructions from the Contracting 
Officer. No construction equipment shall operate within 50 feet of 
aircraft undergoing fuel operations. Open flames are not allowed on the 
ramp except at times authorized by the Contracting Officer.
    (d) Trucks and other motorized equipment entering the airport or 
construction area shall do so only over routes determined by the 
Contracting Officer. Use of runways, aprons, taxiways, or parking areas 
as truck or equipment routes will not be permitted unless specifically 
authorized for such use. Flag personnel shall be furnished by the 
Contractor at points on apron and taxiway for safe guidance of its 
equipment over these areas to assure right of way to aircraft. Areas and 
routes used during the contract must be returned to their original 
condition by the Contractor. The maximum speed allowed at the airport 
shall be established by airport management. Vehicles shall be operated 
so as to be under safe control at all times, weather and traffic 
conditions considered. Vehicles must be equipped with head and tail 
lights during the hours of darkness.

                             (End of clause)



1252.237-70  Qualifications of employees.

    As prescribed in (TAR) 48 CFR 1237.110, insert the following clause:

                 Qualifications of Employees (Oct 1994)

    The Contracting Officer may require dismissal from work of those 
employees which he/she deems incompetent, careless, insubordinate, 
unsuitable or otherwise objectionable, or whose continued employment he/
she deems contrary to the public interest or inconsistent with the best 
interest of national security. The Contractor shall fill out, and cause 
each of its employees on the contract work to fill out, for submission 
to the Government, such forms as may be necessary for security or other 
reasons. Upon request of the Contracting Officer, the Contractor's 
employees shall be fingerprinted. Each employee of the Contractor shall 
be a citizen of the United States of America, or an alien who has been 
lawfully admitted for permanent residence as evidenced by Alien 
Registration Receipt Card Form I-151, or who presents other evidence 
from the Immigration and Naturalization Service that employment will not 
affect his/her immigration status.



1252.237-71  Certification of data.

    As prescribed in (TAR) 48 CFR 1213.7101 and 1237.7003, insert the 
following provisions:

                    Certification of Data (Jan 1996)

    (a) The offeror represents and certifies that to the best of its 
knowledge and belief, the information and/or data (e.g., company 
profile, qualifications, background statements, brochures) submitted 
with its offer is current, accurate, and complete as of the date of its 
offer.
    (b) The offeror understands that any inaccurate data provided to the 
Department of Transportation may subject the offeror, its 
subcontractors, its employees, or its representatives to: (1) 
prosecution for false statements pursuant to 18 U.S.C. 1001 and/or; (2) 
enforcement action for false claims or statements pursuant to the 
Program Fraud Civil Remedies Act of 1986, 31 U.S.C. 3801-2812 and 49 CFR 
part 31 and/or; (3) termination for default under any contract resulting 
from its offer and/or; (4) debarment or suspension.
    (c) The offeror agrees to obtain a similar certification from its 
subcontractors.

 Signature:_____________________________________________________________

 Date:__________________________________________________________________

 Typed Name and Title:__________________________________________________

 Company Name:__________________________________________________________

    This certification concerns a matter within the jurisdiction of an 
agency of the United States and the making of a false, fictitious, or 
fraudulent certification may render the maker subject to prosecution 
under Title 18, United States Code, Section 1001.

                           (End of provision)

[61 FR 392, Jan. 5, 1996]



1252.237-72  Prohibition on advertising.

    As prescribed in (TAR) 48 CFR 1213.7002 and 1237.7003, insert the 
following clause:

                 Prohibition on Advertising (Jan. 1996)

    The contractor or its representatives (including training 
instructors) shall not advertise or solicit business from attendees for 
private, non-Government training during contracted-for training 
sessions. This prohibition extends to unsolicited oral comments, 
distribution or sales of written materials, and/or sales of promotional 
videos or audio tapes.
    The contractor agrees to insert this clause in its subcontracts.

[[Page 568]]

                             (End of clause)

[61 FR 392, Jan. 5, 1996]



1252.237-90  Requirements. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                         Requirements (Oct 1994)

    (a) Except as provided in paragraphs (c) and (d) of this clause, the 
Government will order from the Contractor all of its requirements in the 
area of performance for the supplies and services listed in the schedule 
of this contract.
    (b) Each order will be issued as a delivery order and will list--
    (1) The supplies or services being ordered;
    (2) The quantities to be furnished;
    (3) Delivery or performance dates;
    (4) Place of delivery or performance;
    (5) Packing and shipping instructions;
    (6) The address to send invoices; and
    (7) The funds from which payment will be made.
    (c) The Government may elect not to order supplies and services 
under this contract in instances where the body is removed from the area 
for medical, scientific, or other reason.
    (d) In an epidemic or other emergency, the contracting activity may 
obtain services beyond the capacity of the Contractor's facilities from 
other sources.
    (e) Contracting Officers of the following activities may order 
services and supplies under this contract--

 _______________________________________________________________________

________________________________________________________________________

________________________________________________________________________

________________________________________________________________________

                             (End of clause)



1252.237-91  Area of performance. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                     Area of Performance (Oct 1994)

    (a) The area of performance is as specified in the contract.
    (b) The Contractor shall take possession of the remains at the place 
where they are located, transport them to the Contractor's place of 
preparation, and later transport them to a place designated by the 
Contracting Officer.
    (c) The Contractor will not be reimbursed for transportation when 
both the place where the remains were located and the delivery point are 
within the area of performance.
    (d) If remains are located outside the area of performance, the 
Contracting Officer may place an order with the Contractor under this 
contract or may obtain the services elsewhere. If the Contracting 
Officer requires the Contractor to transport the remains into the area 
of performance, the Contractor shall be paid the amount per mile in the 
schedule for the number of miles required to transport the remains by a 
reasonable route from the point where located to the boundary of the 
area of performance.
    (e) The Contracting Officer may require the Contractor to deliver 
remains to any point within 100 miles of the area of performance. In 
this case, the Contractor shall be paid the amount per mile in the 
schedule for the number of miles required to transport the remains by a 
reasonable route from the boundary of the area of performance to the 
delivery point.

                             (End of clause)



1252.237-92  Performance and delivery. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                   Performance and Delivery (Oct 1994)

    (a) The Contractor shall furnish the material ordered and perform 
the services specified as promptly as possible but not later than 36 
hours after receiving notification to remove the remains, excluding the 
time necessary for the Government to inspect and check results of 
preparation.
    (b) The Government may, at no additional charge, require the 
Contractor to hold the remains for an additional period not to exceed 72 
hours from the time the remains are casketed and final inspection 
completed.

                             (End of clause)



1252.237-93  Subcontracting. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                        Subcontracting (Oct 1994)

    The Contractor shall not subcontract any work under this contract 
without the Contracting Officer's written approval. This clause does not 
apply to contracts of employment between the Contractor and its 
personnel.

[[Page 569]]

                             (End of clause)



1252.237-94  Termination for default. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                   Termination for Default (Oct 1994)

    (a) This clause supplements and is in addition to the Default clause 
of this contract.
    (b) The Contracting Officer may terminate this contract for default 
by written notice without the ten day notice required by paragraph 
(a)(2) of the Default clause if--
    (1) The Contractor, through circumstances reasonably within its 
control or that of its employees, performs any act under or in 
connection with this contract, or fails in the performance of any 
service under this contract and the act or failures may reasonably be 
considered to reflect discredit upon the Department of Transportation in 
fulfilling its responsibility for proper care of remains;
    (2) The Contractor, or its employees, solicits relatives or friends 
of the deceased to purchase supplies or services not under this 
contract. (The Contractor may furnish supplies or arrange for services 
not under this contract, only if representatives of the deceased 
voluntarily request, select, and pay for them.);
    (3) The services or any part of the services are performed by anyone 
other than the Contractor or the Contractor's employees without the 
written authorization of the Contracting Officer;
    (4) The Contractor refuses to perform the services required for any 
particular remains; or
    (5) The Contractor mentions or otherwise uses this contract in its 
advertising in any way.

                             (End of clause)



1252.237-95  Group interment. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                       Group Interment (Oct 1994)

    The Government will pay the Contractor for supplies and services 
provided for remains interred as a group on the basis of the number of 
caskets furnished, rather than on the basis of the number of persons in 
the group.

                             (End of clause)



1252.237-96  Permits. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                           Permits (Oct 1994)

    The Contractor shall meet all State and local licensing requirements 
and obtain and furnish all necessary health department and shipping 
permits at no additional cost to the Government. The Contractor shall 
ensure that all necessary health department permits are in order for 
disposition of the remains.

                             (End of clause)



1252.237-97  Facility requirements. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                    Facility Requirements (Oct 1994)

    (a) The Contractor's building shall have complete facilities for 
maintaining the highest standards for solemnity, reverence, assistance 
to the family, and prescribed ceremonial services.
    (b) The Contractor's preparation room shall be clean, sanitary, and 
adequately equipped.
    (c) The Contractor shall have, or be able to obtain the necessary 
items (e.g., catafalques, structures, trucks, equipment) for religious 
services.
    (d) The Contractor's funeral home, furnishings, grounds, and 
surrounding area shall present a clean and well-kept appearance.

                             (End of clause)



1252.237-98  Preparation history. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following clause:

                     Preparation History (Oct 1994)

    For each body prepared, or for each casket handled in a group 
interment, the Contractor shall state briefly the results of the 
embalming process on a certificate furnished by the Contracting Officer.

                             (End of clause)



1252.237-99  Award to single offeror. (USCG)

    As prescribed in USCG guidance at (TAR) 48 CFR 1237.9000, insert the 
following provision:

                   Award to Single Offeror (Oct 1994)

    (a) Award shall be made to a single offeror.
    (b) Offerors shall include unit prices for each item. Failure to 
include unit prices for each item will be cause for rejection of the 
entire offer.

[[Page 570]]

    (c) The Government will evaluate offers on the basis of the 
estimated quantities shown.
    (d) Award will be made to that responsive, responsible offeror whose 
total aggregate offer is the lowest price to the Government.

                           (End of provision)

                         Alternate I (Oct 1994)

    If mortuary services are procured by negotiations, substitute the 
following paragraph (d) for paragraph (d) of the basic provision:
    (d) Award will be made to that responsive, responsible offeror whose 
total aggregate offer is in the best interest of the Government.



1252.242-70  Dissemination of information--educational institutions.

    As prescribed in (TAR) 48 CFR 1242.203-70(a), insert the following 
clause:

    Dissemination of Information--Educational Institutions (Oct 1994)

    (a) The Department of Transportation (DOT) desires widespread 
dissemination of the results of funded transportation research. The 
Contractor, therefore, may publish (subject to the provisions of the 
``Data Rights'' and ``Patent Rights'' clauses of the contract) research 
results in professional journals, books, trade publications, or other 
appropriate media (a thesis or collection of theses should not be used 
to distribute results because dissemination will not be sufficiently 
widespread). All costs of publication pursuant to this clause shall be 
borne by the Contractor and shall not be charged to the Government under 
this or any other Federal contract.
    (b) Any copy of material published under this clause must contain 
acknowledgment of DOT's sponsorship of the research effort and a 
disclaimer stating that the published material represents the position 
of the author(s) and not necessarily that of DOT. Articles for 
publication or papers to be presented to professional societies do not 
require the authorization of the Contracting Officer prior to release. 
However, two copies of each article shall be transmitted to the 
Contracting Officer at least two weeks prior to release or publication.
    (c) Press releases concerning the results or conclusions from the 
research under this contract shall not be made or otherwise distributed 
to the public without prior written approval of the Contracting Officer.
    (d) Publication under the terms of this clause does not release the 
Contractor from the obligation of preparing and submitting to the 
Contracting Officer a final report containing the findings and results 
of research, as set forth in the schedule of the contract.

                             (End of clause)



1252.242-71  Contractor testimony.

    As prescribed in (TAR) 48 CFR 1242.203-70(b), insert the following 
clause:

                     Contractor Testimony (Oct 1994)

    All requests for the testimony of the Contractor or its employees, 
and any intention to testify as an expert witness relating to: (a) any 
work required by, and/or performed under, this contract; or (b) any 
information provided by any party to assist the Contractor in the 
performance of this contract, shall be immediately reported to the 
Contracting Officer. Neither the Contractor nor its employees shall 
testify on a matter related to work performed or information provided 
under this contract, either voluntarily or pursuant to a request, in any 
judicial or administrative proceeding unless approved by the Contracting 
Officer or required by a judge in a final court order.

                             (End of clause)



1252.242-72  Dissemination of contract information.

    As prescribed in (TAR) 48 CFR 1242.203-70(c), insert the following 
clause:

            Dissemination of Contract Information (Oct 1994)

    The Contractor shall not publish, permit to be published, or 
distribute for public consumption, any information, oral or written, 
concerning the results or conclusions made pursuant to the performance 
of this contract, without the prior written consent of the Contracting 
Officer. Two copies of any material proposed to be published or 
distributed shall be submitted to the Contracting Officer.

                             (End of clause)



1252.242-73  Contracting officer's technical representative.

    As prescribed in (TAR) 48 CFR 1242.7000, insert the following 
clause:

        Contracting Officer's Technical Representative (Oct 1994)

    (a) The Contracting Officer may designate Government personnel to 
act as the Contracting Officer's Technical Representative (COTR) to 
perform functions under the contract such as review and/or inspection 
and acceptance of supplies, services, including construction, and other 
functions of a technical nature. The Contracting Officer will provide a 
written notice of such designation

[[Page 571]]

to the Contractor within five working days after contract award or for 
construction, not less than five working days prior to giving the 
contractor the notice to proceed. The designation letter will set forth 
the authorities and limitations of the COTR under the contract.
    (b) The Contracting Officer cannot authorize the COTR or any other 
representative to sign documents (i.e., contracts, contract 
modifications, etc.) that require the signature of the Contracting 
Officer.

                             (End of clause)



1252.245-70  Government property reports.

    As prescribed in (TAR) 48 CFR 1245.505-70, insert the following 
clause:

                 Government Property Reports (Oct 1994)

    (a) The Contractor shall prepare an annual report of Government 
property in its possession and the possession of its subcontractors.
    (b) The report shall be submitted to the Contracting Officer not 
later than September 15 of each calendar year on Form DOT F 4220.43, 
Contractor Report of Government Property.

                             (End of clause)



1252.247-70  Acceptable service at reduced rates.

    As prescribed in (TAR) 48 CFR 1247.104-370, insert the following 
clause:

             Acceptable Service at Reduced Rates (Oct 1994)

    The Contractor is to use carriers that offer acceptable service at 
reduced rates, if available, to transport supplies under this contract.

                             (End of clause)

[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



1252.247-71  F.o.b. origin information.

    As prescribed in (TAR) 48 CFR 1247.305-70, insert the following 
provision:

                  F.O.B. Origin Information (Oct 1994)

    The offeror shall furnish information with the offer:
    (a) Location of the offeror's actual shipping point(s) (street 
address, city, state, and zip code) from which supplies will be 
delivered to the Government;
    (b) Whether the offered shipping point has a private railroad 
siding, and the name of the rail carrier serving it;
    (c) When the offered shipping point does not have a private siding, 
the names and addresses of the nearest public rail siding and of the 
carrier serving it; and
    (d) The quantity of supplies to be shipped from each shipping point.

                           (End of provision)

                         Alternate I (Oct 1994)

    If delivery is ``f.o.b. origin, contractor's facility,'' and the 
designated facility is not covered by the line-haul transportation rate, 
add the following paragraph to the basic provision:
    (e) The charges required to deliver the shipment to the point where 
the line-haul rate is applicable.

                         Alternate II (Oct 1994)

    When delivery is ``f.o.b. origin, freight allowed,'' add the 
following paragraph to the basic provision:
    (e) The basis on which transportation charges will be allowed, 
including the origin and destination from and to which transportation 
charges will be allowed.
[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



1252.247-72  F.o.b. origin only.

    As prescribed in (TAR) 48 CFR 1247.305-70, insert the following 
provision:

                      F.O.B. Origin Only (Oct 1994)

    Offers are invited on the basis of f.o.b. origin only. Offers 
submitted on any other basis will be rejected as nonresponsive.

                           (End of provision)

[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



1252.247-73  F.o.b. destination only.

    As prescribed in (TAR) 48 CFR 1247.305-70, insert the following 
provision:

                   F.O.B. Destination Only (Oct 1994)

    Offers are invited on the basis of f.o.b. destination only. Offers 
submitted on any other basis will be rejected as nonresponsive.

                           (End of provision)

[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]

[[Page 572]]



1252.247-74  Shipments to ports and air terminals.

    As prescribed in (TAR) 48 CFR 1247.305-70, insert the following 
provision:

             Shipments to Ports and Air Terminals (Oct 1994)

    The Offeror shall furnish the following information with the offer:
    (a) A delivery schedule in number of units and/or long or short 
tons;
    (b) Maximum quantities available per shipment; and
    (c) Other data appropriate to shipment by air carrier.

                           (End of provision)

                         Alternate I (Oct 1994)

    When the delivery term is ``ex dock, pier or warehouse, port of 
importation'' or ``c.& f. destination,'' substitute the following 
paragraph (c) for the paragraph (c) of the basic provision:
    (c) The number of containers or units that can be loaded in a car, 
truck, or other conveyance of the size normally used (specify type and 
size) for the commodity.

                         Alternate II (Oct 1994)

    When the delivery term is ``f.a.s. vessel, port of shipment,'' 
``f.o.b. vessel, port of shipment,'' or ``f.o.b. inland carrier, point 
of exportation,'' substitute the following paragraphs (c), (d) and (e) 
for the paragraph (c) of the basic provision:
    (c) The quantity that can be made available for loading to vessel 
per running day of 24 hours (if acquisition involves a commodity to be 
shipped in bulk);
    (d) The minimum leadtime required to make supplies available for 
loading to vessel; and
    (e) The port and pier or other designation and, when applicable, the 
maximum draft of vessel (in feet) that can be accommodated.

                        Alternate III (Oct 1994)

    When the delivery term is ``c.i.f. destination,'' substitute the 
following paragraphs (c) and (d) for the paragraph (c) of the basic 
provision:
    (c) The number of containers or units that can be loaded in a car, 
truck, or other conveyance of the size normally used (specify type and 
size) for the commodity; and
    (d) The amount and type of marine insurance coverage; e.g., whether 
the coverage is ``With Average'' or ``Free of Particular Average'' and 
whether it covers any special risks or excludes any of the usual risks 
associated with the specific commodity involved.
[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



1252.247-75  F.o.b. designated air carrier's terminal, point of exportation.

    As prescribed in (TAR) 48 CFR 1247.305-70, insert the following 
provision:

  F.O.B. Designated Air Carrier's Terminal, Point of Exportation (Oct 
                                  1994)

    The Offeror shall furnish the following information with the offer:
    (a) A delivery schedule in number of units, type of package, and 
individual weight and dimensions of each package;
    (b) Minimum leadtime required to make supplies available for loading 
into aircraft;
    (c) Name of airport and location to which shipment will be 
delivered; and
    (d) Other data appropriate to shipment by air carrier.

                           (End of provision)

[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



1252.247-76  Nomination of additional ports.

    As prescribed in (TAR) 48 CFR 1247.305-70, insert the following 
provision:

                Nomination of Additional Ports (Oct 1994)

    (a) Offerors may nominate additional ports (including ports in 
Alaska and Hawaii) more favorably located to their shipping points; and
    (b) These ports will be considered in the evaluation of offers if 
they possess all requisite capabilities of the listed ports in relation 
to the supplies being acquired.

                           (End of provision)

[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



1252.247-77  Supply movement in the Defense Transportation System.

    As prescribed in (TAR) 48 CFR 1247.305-71, insert the following 
clause:

     Supply Movement in the Defense Transportation System (Oct 1994)

    (a) The Contractor shall dispatch a Transportation Control Movement 
Document (TCMD) to the appropriate DOD air or water clearance authority 
in accordance with MILSTAMP procedures for all shipments consigned to 
DOD air or water terminal transshipment points; and
    (b) An Export Release must be obtained for supplies to be 
transshipped via a water port of loading to overseas destination, except 
for shipments for which an Export Release is not

[[Page 573]]

required, generally shipments of less than 10,000 pounds, (see paragraph 
202024 of the Military Traffic Management Regulation, AR 55-355, NAVSUP 
4600.70, MCO 4600.14A, AFM 75-2, DLAR 4500.3).

                             (End of clause)

[59 FR 40288, Aug. 8, 1994. Redesignated at 61 FR 50250, Sept. 25, 
1996.]



PART 1253--FORMS--Table of Contents




                  Subpart 1253.2--Prescription of Forms

1253.204  Administrative matters.
1253.215  Contracting by negotiation.
1253.215-270  Price negotiation.
1253.222  Application of labor laws to Government acquisitions.
1253.227-70  Conveyance of invention rights acquired by the Government.
1253.245-70  Report of Government property.

                  Subpart 1253.3--Illustration of Forms

1253.303  Agency forms.

Appendix to Subpart 1253.3 Tar Matrix
Contractor's Release.
Employee Claim for Wage Restitution.
Contractor Report of Government Property.
Contract Pricing Summary.
Contractor's Assignment of Refunds, Rebates, Credits, and Other Amounts.
Cumulative Claim and Reconciliation Statement.
Report of Inventions and Subcontracts.

    Authority:  5 U.S.C. 301; 41 U.S.C. 418(b); 48 CFR 3.1.

    Source:  59 FR 40299, Aug. 8, 1994, unless otherwise noted.



                  Subpart 1253.2--Prescription of Forms



1253.204  Administrative matters.

    The following forms are prescribed for use in the closeout of 
applicable contracts, as specified in (TAR) 48 CFR 1204.804-570:
    (a) Form DOT F 4220.4, Contractor's Release. (See (TAR) 48 CFR 
1204.804-570.) Form DOT F 4220.4 is authorized for local reproduction 
and a copy is furnished for this purpose in Part 1253 of the loose-leaf 
edition of the (TAR) 48 CFR chapter 12.
    (b) Form DOT F 4220.45, Contractor's Assignment of Refunds, Rebates, 
Credits, and Other Amounts. (See (TAR) 48 CFR 1204.804-570.) Form DOT F 
4220.45 is authorized for local reproduction and a copy is furnished for 
this purpose in Part 1253 of the loose-leaf edition of the (TAR) 48 CFR 
chapter 12.
    (c) Form DOT F 4220.46, Cumulative Claim and Reconciliation 
Statement. (See (TAR) 48 CFR 1204.804-570.) Form DOT F 4220.46 is 
authorized for local reproduction and a copy is furnished for this 
purpose in Part 1253 of the loose-leaf edition of the (TAR) 48 CFR 
chapter 12.
    (d) DD Form 882, Report of Inventions and Subcontracts. (See (TAR) 
48 CFR 1204.804-570.) DD Form 882 is authorized for local reproduction 
and a copy is furnished for this purpose in Part 1253 of the loose-leaf 
edition of the (TAR) 48 CFR chapter 12.



1253.215  Contracting by negotiation.



1253.215-270  Price negotiation.

    The following form(s) may be used in connection with requirements 
for obtaining cost or pricing data from offerors or contractors, as 
prescribed in (TAR) 48 CFR 1215.804-6:
    Form DOT F 4220.44, Contract Pricing Summary. (See (TAR) 48 CFR 
1215.804-6). Form DOT F 4220.44 is authorized for local reproduction and 
a copy is furnished for this purpose in (TAR) 48 CFR Part 1253 of the 
loose-leaf edition.



1253.222  Application of labor laws to Government acquisitions.

    The following form is prescribed for use in connection with the 
application of labor laws, as specified in (TAR) 48 CFR 1222.406-9:
    Form DOT F 4220.7, Employee Claim for Wage Restitution. (See (TAR) 
48 CFR 1222.406-9(c)(1).) Form DOT F 4220.7 is authorized for local 
reproduction and a copy is furnished for this purpose in Part 1253 of 
the loose-leaf edition of the (TAR) 48 CFR chapter 12.



1253.227-70  Conveyance of invention rights acquired by the Government.

    The following form is prescribed for including a means for 
contractors to report inventions made in the course of contract 
performance, as specified in 1227.305-4:
    DD Form 882, Report of Inventions and Subcontracts. (See (TAR) 48 
CFR 1227.305-4.) DD Form 882 is authorized for local reproduction and a 
copy is furnished for this purpose in Part 1253

[[Page 574]]

of the loose-leaf edition of the (TAR) 48 CFR chapter 12.



1253.245-70  Report of Government property.

    The following form is prescribed for use by contractors to report 
Government property, as specified in (TAR) 48 CFR 1245.505-14:
    Form DOT F 4220.43, Contractor Report of Government Property. (See 
(TAR) 48 CFR 1245.505-14.) Form DOT F 4220.43 is authorized for local 
reproduction and a copy is furnished for this purpose in Part 1253 of 
the loose-leaf edition of the (TAR) 48 CFR chapter 12.



                  Subpart 1253.3--Illustration of Forms



1253.303  Agency forms.

    This subpart contains illustrations of DOT and other agency forms 
specified by the TAR for use in DOT acquisitions.
      

[[Page 575]]

                       Appendix to Subpart 1253.3

                                                                                           TAR Matrix                                                                                           
------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------
                                                                                                                      Principle type and/or purpose of contract                                 
                                                               P or                -------------------------------------------------------------------------------------------------------------
        Provision or clause               Prescribed in         C      IBR    UCF    FP    CR    FP    CR    FP    CR    FP    CR   T&M         COM                     IND                 UTL 
                                                                                    SUP   SUP   R&D   R&D   SVC   SVC   CON   CON    LH   LMV   SVC   DDR   A&E   FAC   DEL   TRN     SP    SVC 
------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------
1252.209-70  Disclosure of           1209.507                    P     Yes      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     .....   A   
 Conflicts of Interest.                                                                                                                                                                         
1252.211-70  Brand Name or Equal...  1211.011                    P     Yes      L   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     .....   A   
1252.211-71  Index for               1211.011                     C    Yes      I   A     A     A    .....  ...  .....  A     A     ...  .....  ...   A     ...   A     A    .....   A     .....
 Specifications.                                                                                                                                                                                
1252.215-70  Key Personnel and/or    1215.106                    P      No      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     .....   A   
 Facilities.                                                                                                                                                                                    
1252.216-70  Evaluation of Offers    1216.203-470                P     Yes      M   A    .....  A    .....  A    .....  A    .....  A     A     A     A     A     A     A     A     .....   A   
 Subject to an Economic Price                                                                                                                                                                   
 Adjustment Clause.                                                                                                                                                                             
1252.216-71  Determination of Award  1216.405(a)                 P      No      I   ...   A     ...   A     ...   A     ...   A     A    .....  A     A     ...  .....  A     A     .....  .....
 Fee.                                                                                                                                                                                           
1252.216-72  Performance Evaluation  1216.405(b)                 P      No      I   ...   A     ...   A     ...   A     ...   A     A    .....  A     A     ...  .....  A     A     .....  .....
 Plan.                                                                                                                                                                                          
1252.216-73  Distribution of Award   1216.405(c)                 P     Yes      I   ...   A     ...   A     ...   A     ...   A     A    .....  A     A     ...  .....  A     A     .....  .....
 Fee.                                                                                                                                                                                           
1252.216-74  Settlement of Letter    1216.603-4                  P      No      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     .....   A   
 Contract.                                                                                                                                                                                      
1252.217-71  Delivery and Shifting   1217.7000(b) and (c)        P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
 of Vessel.                                                                                                                                                                                     
1252.217-72  Performance...........  1217.7000(b) and (c)        P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
1252.217-73  Inspection and Manner   1217.7000(b) and (c)        P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
 of Doing Work.                                                                                                                                                                                 
1252.217-74  Subcontracts..........  1217.7000 (b) and (c)       P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
12542.217-75  Lay Days.............  1217.7000 (b) and (c)       P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
1252.217-76  Liability and           1217.7000 (b) and (c)       P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
 Insurance.                                                                                                                                                                                     
1252.217-77  Title.................  1217.7000 (b) and (c)       P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
1252.217-78  Discharge of Liens....  1217.7000 (b) and (c)       P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
1252.217-79  Delays................  1217.7000 (b) and (c)       P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
1252.217-80  Department of Labor     1217.7000 (b) and (c)       P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
 Safety and Health Regulations for                                                                                                                                                              
 Ship Repair.                                                                                                                                                                                   
1252.217-81  Guarantee.............  1217.7000(d)                P     Yes      I   ...  .....  ...  .....  A    .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
1252.219-70  Small Business and      1219.708-70                 P     Yes      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     .....   A   
 Small Disadvantaged Business                                                                                                                                                                   
 Subcontracting Report.                                                                                                                                                                         
1252.222-70  Strikes or Picketing    1222.101-71(a)              P     Yes      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A      A      A   
 Affecting Timely Completion of the                                                                                                                                                             
 Contract Work.                                                                                                                                                                                 
1252.222-71  Strikes or Picketing    1222.101-71(b)              P     Yes      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A      A      A   
 Affecting Access to a DOT Facility.                                                                                                                                                            
1252.223-70  Removal or Disposal of  1223.303                    P      No      K   ...  .....  ...  .....  A     A     A     A     A    .....  ...   A     ...   A     ...  .....   A     .....
 Hazardous Substances--Applicable                                                                                                                                                               
 Licenses and Permits.                                                                                                                                                                          
1252.223-71  Accident and Fire       1223.7000(a)                P     Yes      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A      A      A   
 Reporting.                                                                                                                                                                                     
1252.223-72  Protection of Human     1223.7000(b)                P     Yes      I   A     A     A     A     A     A     ...  .....  A    .....  ...  .....  ...  .....  A    .....   A     .....
 Subjects.                                                                                                                                                                                      

[[Page 576]]

                                                                                                                                                                                                
1252.228-70  Loss of or Damage to    1228.306-70 (a) and (b)     P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  A    .....  ...  .....  ...  .....  ...  .....   A     .....
 Leased Aircraft.                                                                                                                                                                               
1252.228-71  Fair Market Value of    1228.306-70 (a) and (c)     P      No      I   ...  .....  ...  .....  A     A     ...  .....  A    .....  ...  .....  ...  .....  ...  .....   A     .....
 Aircraft.                                                                                                                                                                                      
1252.228-72  Risk and Indemnities..  128.306-70 (a) and (d)      P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  A    .....  ...  .....  ...  .....  ...  .....   A     .....
1252.231-70  Date of Incurrence of   1231.205-32                 P      No      I   ...   A     ...   A     ...   A     ...   A     ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
 Costs.                                                                                                                                                                                         
1252.236-70  Special Precautions     1236.570                    P     Yes      I   ...  .....  ...  .....  ...  .....  A     A     A    .....  ...   A     A     A     ...  .....   A      A   
 for Work at Operating Airports.                                                                                                                                                                
1252.237-70  Qualifications of       1237.110                    P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  A    .....  ...  .....  ...  .....   A     .....
 Employees.                                                                                                                                                                                     
1252.237-71  Certification of Data.  1237.7003                   P      No      K   ...  .....  ...  .....  A     A     ...  .....  ...  .....  A    .....  ...  .....  A    .....   A     .....
1252.237-72  Prohibition on          1237.7003                    C     No      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  A    .....  ...  .....  A    .....   A     .....
 Advertising.                                                                                                                                                                                   
1252.242-70  Dissemination of        1242.203-70(a)              P     Yes      I   ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....       
 Information--Education                                                                                                                                                                         
 Institutions.                                                                                                                                                                                  
1252.242-71  Contractor Testimony..  1242.203-70(b)              P     Yes      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A      A      A   
1252.242-72  Dissemination of        1242.203-70(c)              P     Yes      I   A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     A     .....   A   
 Contract Information.                                                                                                                                                                          
1252.242-73  Contracting Officers    1242.7000                   P     Yes      I   A     A     A     A     A     A     A     A     A     A     ...   A     A     A     A     A      A     .....
 Technical Representative.                                                                                                                                                                      
1252.245-70  Government Property     1245.505-70                 P     Yes      I   A     A     A     A     A     A     A     A     A    .....  A     A     A     A     A     A      A     .....
 Reports.                                                                                                                                                                                       
1252.247-70  Acceptable Service at   1247.104-370                 C    Yes      I   ...   A     ...  .....  ...   A     ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
 Reduced Rates.                                                                                                                                                                                 
1252.247-71  F.O.B. Origin           1247.305-70                 P     Yes      L   A    .....  ...  .....  ...  .....  ...  .....  ...   A     ...  .....  ...  .....  A    .....   A     .....
 Information.                                                                                                                                                                                   
1252.247-72  F.O.B. Origin Only....  1247.305-70                 P     Yes      L   A    .....  ...  .....  ...  .....  ...  .....  ...   A     ...  .....  ...  .....  A    .....   A     .....
1252.247-73  F.O.B. Destination      1247.305-70                 P     Yes      L   A    .....  ...  .....  ...  .....  ...  .....  ...   A     ...  .....  ...  .....  A    .....   A     .....
 Only.                                                                                                                                                                                          
1252.247-74  Shipments to Ports and  1247.305-70                 P     Yes      L   A    .....  ...  .....  ...  .....  ...  .....  ...   A     ...  .....  ...  .....  A    .....   A     .....
 Air Terminals.                                                                                                                                                                                 
1252.247-75  F.O.B. Designated Air   1247.305-70                 P     Yes      L   A    .....  ...  .....  ...  .....  ...  .....  ...   A     ...  .....  ...  .....  A    .....   A     .....
 Carrier's Terminal, Port of                                                                                                                                                                    
 Exportation.                                                                                                                                                                                   
1252.247-76  Nominatin of            1247.305-70                 P     Yes      L   A    .....  ...  .....  ...  .....  ...  .....  ...   A     ...  .....  ...  .....  A    .....   A     .....
 Additional Ports.                                                                                                                                                                              
1252.247-77  Supply Movement in the  1247.305-71                  C    Yes      F   A    .....  ...  .....  ...  .....  ...  .....  ...   A     ...  .....  ...  .....  A    .....   A     .....
 Defense Transportation System.                                                                                                                                                                 
FAA 1252.225-90  Buy American        FAA 1225.9005               P      No      I   A     A     A     A     ...  .....  A     A     ...  .....  ...  .....  ...   A     ...  .....  .....  .....
 Certificate-Steel and Manufactured                                                                                                                                                             
 Products.                                                                                                                                                                                      
FAA 1252.225-91  Buy American Steel  FAA 1225.9005               P     Yes      I   A     A     A     A     ...  .....  A     A     ...  .....  ...  .....  ...   A     ...  .....  .....  .....
 and Manufactured Products.                                                                                                                                                                     
USCG 1252.210-90  Bar Coding         USCG 1210.011-90 and        P     Yes      I   A     A     ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
 Requirement.                         1213.507-90                                                                                                                                               
USCG 1252.213-90  Evaluation Factor  USCG 1213.107-90            P      No      M   ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....  ...  .....   A     .....
 for Coast Guard Performance of Bar                                                                                                                                                             
 Coding Requirement.                                                                                                                                                                            
USCG 1252.220-90  Local Hire.......  USCG 1220.9001              P     Yes      I   ...  .....  ...  .....  A     A     A     A     ...  .....  A    .....  A    .....  A    .....  .....   A   

[[Page 577]]

                                                                                                                                                                                                
USCG 1252.228-90  Notification of    USCG 1228.9000              P      No      I   ...  .....  ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  .....  .....
 Miller Act Payment Bond Protection.                                                                                                                                                            
USCG 1252.237-90  Requirements.....  USCG 1237.9000              P      No      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....  .....  .....
USCG 1252.237-91  Area of            USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
 Performance.                                                                                                                                                                                   
USCG 1252.237-92  Performance and    USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
 Delivery.                                                                                                                                                                                      
USCG 1252.237-93  Subcontracting...  USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
USCG 1252.237-94  Termination for    USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
 Default.                                                                                                                                                                                       
USCG 1252.237-95  Group Interment..  USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
USCG 1252.237-96  Permits..........  USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
USCG 1252.237-97  Facility           USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
 Requirements.                                                                                                                                                                                  
USCG 1252.237-98  Preparation        USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
 History.                                                                                                                                                                                       
USCG 1252.237-99  Award to Single    USCG 1237.9000              P     Yes      I   ...  .....  ...  .....  A     A     ...  .....  ...  .....  ...  .....  ...  .....  A    .....   A     .....
 Offeror.                                                                                                                                                                                       
------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------
Key:  P or C=Provision or Clause;  IBR=Is Incorporation By Reference authorized?;  UCF=Uniform Contract Format Section, when applicable.                                                        
Principle type and/or purpose of contract:  R=Required;  A=Required-When-Applicable;  O=Optional;  X=Revision;  FP SUP=Fixed-Price Supply;  CR SUP=Cost-Reimbursement Supply;  FP R&D=Fixed-    
  Price Research and Development;  CR R&D=Cost-Reimbursement Research and Development;  FP SVC=Fixed-Price Service;  CR SVC=Cost Reimbursement Service;  FP CON=Fixed-Price construction;  CR   
  CON=Cost Reimbursement Construction;  T&M LH=Time & Material/Labor Hours;  LMV=Leasing of Motor Vehicles;  COM SVC=Communication Services;  DDR=Dismantling, Demolition, or Removal of        
  Improvements;  A-E=Architect-Engineering;  FAC=Facilities;  IND DEL=Indefinite Delivery;  TRN=Transportation;  SP=Small Purchases;  UTL SVC=Utility Services.                                 


[[Page 578]]

[GRAPHIC] [TIFF OMITTED] TR14MY97.007


[[Page 579]]

[GRAPHIC] [TIFF OMITTED] TC02MR91.003


[[Page 580]]

[GRAPHIC] [TIFF OMITTED] TR14MY97.008


[[Page 581]]

[GRAPHIC] [TIFF OMITTED] TC02MR91.005


[[Page 582]]

[GRAPHIC] [TIFF OMITTED] TC02MR91.006


[[Page 583]]

[GRAPHIC] [TIFF OMITTED] TR14MY97.009


[[Page 584]]

[GRAPHIC] [TIFF OMITTED] TR14MY97.010


[[Page 585]]

[GRAPHIC] [TIFF OMITTED] TC02MR91.009


[[Page 586]]

[GRAPHIC] [TIFF OMITTED] TC02MR91.010


[[Page 587]]

[59 FR 40299, Aug. 8, 1994, as amended at 60 FR 55802, Nov. 3, 1995; 61 
FR 393, Jan. 5, 1996; 61 FR 50251, Sept. 25, 1996; 62 FR 26421, May 14, 
1997]

[[Page 589]]



                   CHAPTER 13--DEPARTMENT OF COMMERCE




                          (Parts 1300 to 1399)

  --------------------------------------------------------------------

                          SUBCHAPTER A--GENERAL
Part                                                                Page
1301            General.....................................         591
1302

[Reserved]

1303            Improper business practices and personal 
                    conflicts of interest...................         592
1304

[Reserved]

           SUBCHAPTER B--COMPETITION AND ACQUISITION PLANNING
1305-1308

  [Reserved]

1309            Contractor qualifications...................         594
          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
1313            Small purchase and other simplified purchase 
                    procedures..............................         596
1314

[Reserved]

1315            Contracting by negotiation..................         596
1316            Types of contracts..........................         598
1317            Special contracting methods.................         598
                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
1319            Small business and small disadvantaged 
                    business concerns.......................         600
1322-1325

  [Reserved]

             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
1331

[Reserved]

1332            Contract financing..........................         601
1333            Protests, disputes and appeals..............         601
             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING
1334

[Reserved]

1336            Construction and architect-engineer 
                    contracts...............................         604

[[Page 590]]

1337

[Reserved]

                    SUBCHAPTER G--CONTRACT MANAGEMENT
1342            Contract administration.....................         605
1345

[Reserved]

1349            Termination of contracts....................         605
                     SUBCHAPTER H--CLAUSES AND FORMS
1352            Solicitation provisions and contract clauses         607
1353            Forms.......................................         619

[[Page 591]]



                          SUBCHAPTER A--GENERAL





PART 1301--GENERAL--Table of Contents




              Subpart 1301.1--Purpose, Authority, Issuance

Sec.
1301.100  Scope of subpart.
1301.101  Purpose.
1301.102  Authority.
1301.103  Applicability.
1301.104  Issuance.
1301.104-1  Publication and code arrangement.
1301.104-2  Arrangement of regulations.
1301.104-3  Copies.

                    Subparts 1301.2-1301.5 [Reserved]

       Subpart 1301.6--Contracting Authority and Responsibilities

1301.603-70  Ratification of unauthorized contract awards.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486 (c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.

    Source:  49 FR 12956, Mar. 30, 1984, unless otherwise noted.



              Subpart 1301.1--Purpose, Authority, Issuance



1301.100  Scope of subpart.

    This subpart states the relationship of the Commerce Acquisition 
Regulation (CAR) to the Federal Acquisition Regulation (FAR). This 
subpart also explains the purpose, authority and issuance of the CAR.



1301.101  Purpose.

    (a) Chapter 13 of Title 48 of the Code of Federal Regulations shall 
be known as the Commerce Acquisition Regulation (CAR).
    (b) The purpose of the CAR is to implement and supplement the FAR 
within the Department of Commerce. Since the CAR is intended to 
supplement and implement the FAR without paraphrasing or duplicating FAR 
language, the CAR should be read in relation to the FAR.
[49 FR 12956, Mar. 30, 1984, as amended at 51 FR 15329, Apr. 23, 1986]



1301.102  Authority.

    The CAR is prescribed by the Department Procurement Executive 
pursuant to a delegation initiating from the Secretary of Commerce in 
accordance with the Federal Property and Administrative Services Act of 
1949, as amended, and other applicable law and regulation.



1301.103  Applicability.

    The FAR and CAR apply to all acquisitions within the Department of 
Commerce.



1301.104  Issuance.



1301.104-1  Publication and code arrangement.

    (a) The CAR is published in (1) daily issues of the Federal 
Register, (2) cumulative form in the Code of Federal Regulations (CFR), 
and (3) a separate loose-leaf edition.
    (b) The CAR is issued as chapter 13 of title 48 of the CFR.



1301.104-2  Arrangement of regulations.

    (a) General. The CAR is divided into the same parts, subparts, 
sections, subsections and paragraphs as the FAR. When FAR coverage is 
adequate by itself, there will be no corresponding CAR coverage.
    (b) Numbering. Where the CAR implements the FAR, the CAR part, 
subpart, section or further subdivision will be numbered the same as the 
corresponding FAR part, subpart, section, or further subdivision except 
that the CAR implementation will be preceded by a 13 or 130 so that 
there are four numbers to the left of the first decimal. Where the CAR 
supplements the FAR, supplementing material will be assigned the number 
70 and above. The placement of the sequence of 70 numbers in relation to 
the decimal point will depend on what division of the FAR is 
supplemented.

[[Page 592]]

    (c) References and citations. (2) This regulation may be referred to 
as the Commerce Acquisition Regulation (CAR).
    (3) References to FAR materials will include FAR and the identifying 
number, for example, FAR 1.402. Reference to CAR materials will consist 
of the identifying number, for example 1301.402.



1301.104-3  Copies.

    (a) Copies of the CAR in Federal Register or CFR form may be 
purchased from the Superintendent of Documents, Government Printing 
Office (GPO), Washington, DC 20402. Requests should reference the CAR as 
chapter 13 of title 48 of the Code of Federal Regulations.
    (b) Loose-leaf copies of the CAR are distributed within the 
Department by the Procurement Executive.
[49 FR 12956, Mar. 30, 1984, as amended at 51 FR 15329, Apr. 23, 1986]



                    Subparts 1301.2-1301.5 [Reserved]



       Subpart 1301.6--Contracting Authority and Responsibilities



1301.603-70  Ratification of unauthorized contract awards.

    (a) The Department is not bound by any formal or informal type of 
agreement or contractual commitment which is made by persons who are not 
delegated contracting authority. When these unauthorized acts are 
discovered they shall be immediately reported to the Head of the 
Contracting Activity concerned. The Head of the Contracting Activity 
shall:
    (1) Immediately inform any person who is performing work as a result 
of an unauthorized commitment that the work is being performed at that 
person's risk;
    (2) Decide whether ratification of the unauthorized act is proper, 
and take appropriate action.
[49 FR 12956, Mar. 30, 1984, as amended at 60 FR 47309, Sept. 12, 1995]



PART 1302 [RESERVED]






PART 1303--IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST--Table of Contents




                       Subpart 1303.1--Safeguards

Sec.
1303.101-3  Agency regulations.

      Subpart 1303.2--Contractor Gratuities to Government Personnel

1303.203  Reporting procedures.

   Subpart 1303.3--Reports of Identical Bids and Suspected Antitrust 
                               Violations

1303.302-70  Reporting requirements.

                     Subpart 1303.4--Contingent Fees

1303.409  Misrepresentations or violations of the Covenant Against 
          Contingent Fees.

            Subpart 1303.5--Other Improper Business Practices

1303.502  Subcontractor kickbacks.
    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.
    Source:  49 FR 12959, Mar. 30, 1984, unless otherwise noted.



                       Subpart 1303.1--Safeguards



1303.101-3  Agency regulations.

    The agency rules implementing Executive Order 11222 are contained in 
the Department Administrative Order on Employee Responsibilities and 
Conduct (DAO 202-735).



      Subpart 1303.2--Contractor Gratuities to Government Personnel



1303.203  Reporting procedures.

    Suspected violations of the Gratuities clause shall be reported to 
the head of the contracting office in writing detailing the 
circumstances. The head of the contracting office will evaluate the 
report and if the allegations appear to support a violation the matter 
will be referred to the Office of Inspector General in accordance with 
the Department Administrative Order

[[Page 593]]

on Inspector General Investigations (DAO 207-10).



   Subpart 1303.3--Reports of Identical Bids and Suspected Antitrust 
                               Violations



1303.302-70  Reporting requirements.

    (a) Executive Order 12430 revoked the requirement of Executive Order 
10936 to submit a report to the Attorney General on identical bids.
    (b) Suspected anti-competitive practices and antitrust law 
violations as described in FAR 3.301 and FAR 3.303 shall be reported to 
the general counsel through the Head of the Contracting Activity. A copy 
of the report shall be sent to the Procurement Executive concurrently 
with the submission to the general counsel.



                     Subpart 1303.4--Contingent Fees



1303.409  Misrepresentations or violations of the Covenant Against Contingent Fees.

    Suspected violations of the Covenant Against Contingent Fees shall 
be reported to the Office of Inspector General in accordance with the 
Department Administrative Order on Inspector General Investigations (DAO 
207-10).



            Subpart 1303.5--Other Improper Business Practices



1303.502  Subcontractor kickbacks.

    Suspected violations of the Anti-Kickback Act shall be reported to 
the Office of Inspector General in accordance with the Department 
Administrative Order on Inspector General Investigations (DAO 207-10).



PART 1304 [RESERVED]




[[Page 594]]



           SUBCHAPTER B--COMPETITION AND ACQUISITION PLANNING





PARTS 1305-1308 [RESERVED]






PART 1309--CONTRACTOR QUALIFICATIONS--Table of Contents




           Subpart 1309.1--Responsible Prospective Contractors

Sec.
1309.106  Preaward surveys.
1309.106-70  Preaward surveys for ship construction, ship alteration, 
          and ship repair.

         Subpart 1309.4--Debarment, Suspension and Ineligibility

1309.470-4  Procedures on debarment.
1309.470-7  Procedures on suspension.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.

    Source:  49 FR 12960, Mar. 30, 1984, unless otherwise noted.



           Subpart 1309.1--Responsible Prospective Contractors



1309.106  Preaward surveys.

[51 FR 15330, Apr. 23, 1986]



1309.106-70  Preaward surveys for ship construction, ship alteration, and ship repair.

    (a) General. The contracting officer shall request a preaward survey 
of a prospective contractor for contracts involving ship construction, 
ship alteration, or ship repair, where the cost or price of the contract 
is anticipated to be in excess of $100,000, and the information on hand 
is not sufficient to make a determination regarding responsibility. The 
contracting officer may request a preaward survey of a prospective 
contractor for contracts involving ship construction, ship alteration, 
or ship repair, where the cost or price of the contract is anticipated 
to be $100,000 or less, if the circumstances justify the cost of the 
survey.
    (b) Extent of preaward survey. The contracting officer shall 
determine the manner and extent of the preaward survey based upon the 
specific requirements of the contract. At a minimum, the contracting 
officer shall request a preaward survey for contracts involving ship 
construction, ship alteration, and ship repair where the contracting 
officer cannot affirmatively determine that the prospective contractor's 
facility is adequate for the work to be performed. For the purpose of 
this section, the prospective contractor's facility includes the land, 
buildings, shop spaces, dock facilities, drydock or marine railways, and 
plant security and safety.
    (c) Examples of specific concern. The contracting officer shall 
coordinate efforts with technical and requirements personnel to identify 
areas of specific concern for the preaward survey. The following 
examples illustrate areas which may be of specific concern to the 
preaward survey team, depending on the nature of the work to be 
performed:
    (1) Acceptable facilities and equipment for special production 
techniques (e.g., unique welding procedures, special test fixtures, or 
production equipment);
    (2) Adequate size and lift capacity for the drydock or marine 
railway;
    (3) Well maintained drydock and lifting equipment and acceptable 
preventative maintenance of these items;
    (4) Acceptable dock master and crew who are experienced in operating 
the equipment and lifting a vessel of comparable size and weight;
    (5) Adequate drydock or pier utilities to support the vessel, 
including electrical power, steam, potable water, fire fighting 
capability, sewage disposal, and telephone service;
    (6) Responsible subcontractors;
    (7) Contractor's demonstrated ability to monitor and coordinate 
subcontractor performance;
    (8) Contractor's demonstrated ability to conduct dock and sea 
trials;
    (9) Contractor's demonstrated ability to protect the vessel and yard 
and vessel personnel, including safety and security programs or 
individual plans;

[[Page 595]]

    (10) Adequate secure storage facilities for Government property; and
    (11) The depth of water in the navigable waterway and the pier where 
the vessel will be berthed.
    (d) Preaward survey team. The contracting officer may use any of the 
following individuals to form the preaward survey team:
    (1) A cost or price analyst or cognizant audit agency for review of 
the contractor's financial and accounting systems;
    (2) Technical or requirements personnel from the cognizant marine 
center or office of marine operations, for technical, production, or 
quality assurance evaluations; and
    (3) Representatives of the contracting officer for management and 
administrative evaluations.
    (e) On-site survey. If it is necessary to conduct a survey at the 
proposed site where the work is to be performed, the contracting officer 
shall coordinate the visit with the prospective contractor or 
subcontractor.
    (f) Reports. The surveying team shall comply with the applicable 
reporting requirements of FAR 9.106-4. When using the short-form 
preaward survey report prescribed in FAR 9.106-4(d), the surveying team 
shall provide information on the following at a minimum:
    (1) The depth of water in the navigable waterway and the pier where 
the vessel will be berthed;
    (2) The condition of the drydock or marine railway where the work is 
to be performed;
    (3) Availability of adequate utilities and services for the vessel;
    (4) Evidence of prospective contractor or subcontractor financial 
problems or poor past performance.
    (g) Contracting officer determination. Upon completion of the 
preaward survey, the contracting officer shall determine whether the 
prospective contractor and subcontractors are responsible.
[51 FR 15330, Apr. 23, 1986]



         Subpart 1309.4--Debarment, Suspension and Ineligibility



1309.470-4  Procedures on debarment.

    Decision making process. Upon receipt of a debarment recommendation, 
the Procurement Executive shall review all available evidence and shall 
promptly determine whether or not to proceed with debarment. The 
Procurement Executive may refer the matter to the Office of Inspector 
General for further investigation. After completion of any additional 
review or investigations, the Procurement Executive shall make a written 
determination. A copy of this determination shall be promptly sent to 
the initiating contracting office. (See FAR 9.406-3(b).)
[60 FR 47309, Sept. 12, 1995]



1309.470-7  Procedures on suspension.

    Decision making process. Procedures for the decision making process 
of suspensions are the same as those contained in 1309.470-4 except that 
an initial decision for suspension results in immediate suspension. (See 
FAR 9.407-3(b).)
[60 FR 47309, Sept. 12, 1995]

[[Page 596]]



          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES





PART 1313--SMALL PURCHASE AND OTHER SIMPLIFIED PURCHASE PROCEDURES--Table of Contents




    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.



                         Subpart 1313.1--General



1313.106-70  Technical evaluation and written or oral discussion procedure for negotiated small purchases.

    (a) Technical evaluation. A technical evaluation may be requested 
for negotiated small purchases, at the discretion of the contracting 
officer. The manner and extent of the technical evaluation shall be 
determined by the contracting officer, except that the technical 
evaluation shall not be as formal or as extensive as required for 
procurements above the small purchase dollar threshold.
    (b) Written or oral discussions. Written or oral discussions may be 
conducted with all qualified sources which submit quotations for 
negotiated small purchases. The contracting officer shall determine the 
manner, extent, and need for written or oral discussions, except that 
discussions shall not be as formal or as extensive as required for 
procurements above the small purchase dollar threshold.
[49 FR 12961, Mar. 30, 1984]



PART 1314 [RESERVED]






PART 1315--CONTRACTING BY NEGOTIATION--Table of Contents




  Subpart 1315.4--Solicitation and Receipt of Proposals and Quotations

Sec.
1315.413-2  Alternate II.

                  Subpart 1315.5--Unsolicited Proposals

1315.504  Advance guidance.
1315.506  Agency procedures.

                        Subpart 1315.6 [Reserved]

                    Subpart 1315.8--Price Negotiation

1315.805-70  Audit as an aid in proposal analysis.

                         Subpart 1315.9--Profit

1315.902  Policy.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.

    Source:  49 FR 12961, Mar. 30, 1984, unless otherwise noted.



  Subpart 1315.4--Solicitation and Receipt of Proposals and Quotations



1315.413-2  Alternate II.

    The procedures described in FAR 15.413-2 may be used if approved by 
the Head of the Contracting Activity or designee.



                  Subpart 1315.5--Unsolicited Proposals



1315.504  Advance guidance.

    (a) When it appears that a person or firm is interested in making a 
proposal, that person or firm should be referred to the head of the 
contracting office concerned who will provide instructions for 
submission of an unsolicited proposal.
    (b) Heads of contracting offices shall provide instructions for 
submission of unsolicited proposals to each person or firm which 
expresses an interest in submitting an unsolicited proposal.
[49 FR 12961, Mar. 30, 1984, as amended at 60 FR 47309, Sept. 12, 1995]



1315.506  Agency procedures.

    (a) Promptly after receipt of an unsolicited proposal which conforms 
to this regulation, the head of the contracting

[[Page 597]]

office shall forward a copy of the proposal along with instructions for 
technical evaluation of unsolicited proposals to the appropriate program 
office for technical evaluation. If more than one Department activity 
has an interest in a proposal, copies of the proposal shall be 
circulated to each interested office.
    (b) Program offices receiving unsolicited proposals for evaluation 
shall conduct the evaluation in accordance with this subpart 1315.5, FAR 
Subpart 15.5, and any additional guidance provided by the Office of 
Procurement and Federal Assistance.
    (c) Program offices shall complete the recommendation and 
evaluations and submit them along with all copies of the unsolicited 
proposal, and a written justification for a noncompetitive procurement 
action if appropriate, to the head of the appropriate contracting office 
within 60 days of receipt of a proposal for evaluation.
    (d) No part of an unsolicited proposal shall be duplicated or 
circulated outside of the evaluation office. Each unsolicited proposal 
shall be closely safeguarded to prevent disclosure of any restricted 
data. Only heads of contracting offices or their designees may duplicate 
unsolicited proposals and then only to facilitate evaluation by more 
than one technical evaluation office.
[49 FR 12961, Mar. 30, 1984, as amended at 60 FR 47309, Sept. 12, 1995]



                        Subpart 1315.6 [Reserved]



                    Subpart 1315.8--Price Negotiation



1315.805-70  Audit as an aid in proposal analysis.

    (a) Preaward audits should not be routinely requested for actions 
below the dollar threshold specified in FAR 15.805-5. Before requesting 
audits below the dollar threshold, the contracting office should 
consider using price or cost analysis techniques, recent audit reports, 
price negotiation memoranda, and other relevant information regarding 
the offer to establish the reasonableness of price. However, audits 
should be considered for proposals below the specified dollar thresholds 
in the following circumstances:
    (1) The contracting officer has reason to doubt the adequacy of the 
contractor's accounting policies or cost systems;
    (2) The contractor has substantially changed its methods or levels 
of operation;
    (3) Previous unfavorable experience indicates that the contractor's 
estimating, accounting, or purchasing methods may be unreliable; or
    (4) The proposal concerns a new product for which cost experience is 
lacking.
[49 FR 12961, Mar. 30, 1984, as amended at 60 FR 47309, Sept. 12, 1995]



                         Subpart 1315.9--Profit



1315.902  Policy.

    (a) Except as provided in (b) and (c) of this section, a structured 
approach for determining profit or fee prenegotiation objectives shall 
be used in the negotiation of all contracts, subcontracts, and contract 
modifications above $100,000 where adequate price competition does not 
exist. A structured approach for determining profit or fee 
prenegotiation objectives may be used at lower dollar thresholds.
    (b) Regardless of whether price competition exists, the structured 
approach for determining profit or fee prenegotiation objectives is not 
required for negotiation of contracts, subcontracts, and contract 
modifications for the following:
    (1) Architect--engineering contracts;
    (2) Management contracts for operation or maintenance of Government 
facilities;
    (3) Construction contracts;
    (4) Contracts primarily requiring delivery of material supplied by 
subcontractors;
    (5) Termination settlements;
    (6) Cost-plus-award-fee contracts; and
    (7) Unusual pricing situations where the structured approach has 
been determined to be unsuitable. This exception must be justified in 
writing and signed by the head of the contracting office.
    (c) In many circumstances, an examination of cost and profits is not 
required. Where adequate price competition exists and in other 
situations where cost analysis is not required

[[Page 598]]

(e.g., established catalog or market prices of commercial items sold in 
substantial quantities to the general public or prices set by law or 
regulation), contracts may be awarded without regard to the amount of 
profit involved.
    (d) Additional internal instruction on the use of the structured 
approach can be found in Procurement Letters or policy manuals issued by 
the Office of Procurement and Federal Assistance.



PART 1316--TYPES OF CONTRACTS--Table of Contents




                        Subpart 1316.3 [Reserved]

                   Subpart 1316.4--Incentive Contracts

Sec.
1316.404-2  Cost-plus-award-fee contracts.

                        Subpart 1316.6 [Reserved]

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.

    Source:  49 FR 12962, Mar. 30, 1984, unless otherwise noted.



                        Subpart 1316.3 [Reserved]



                   Subpart 1316.4--Incentive Contracts



1316.404-2  Cost-plus-award-fee contracts.

    (d) Fee determination plans. The award fee determination plan shall 
include both technical performance (including scheduling as appropriate) 
and business management consideration tailored to the needs of the 
particular situation. The goals and evaluation criteria should be 
results-oriented. The award fee should concentrate on the end product of 
the contract. However, equal employment opportunity, small business 
programs, and functional management areas, such as safety and security, 
cannot be disregarded and may be appropriately part of the criteria upon 
which to base the award fee. Specific goals or objectives should be 
established in relation to each performance evaluation criterion against 
which contractor performance is measured.



                        Subpart 1316.6 [Reserved]



PART 1317--SPECIAL CONTRACTING METHODS--Table of Contents




                    Subparts 1317.4-1317.5 [Reserved]

 Subpart 1317.70--Contracts for Ship Construction, Ship Alteration, and 
                               Ship Repair

Sec.
1317.7001  Solicitation provisions and contract clauses.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.



                    Subparts 1317.4-1317.5 [Reserved]



 Subpart 1317.70--Contracts for Ship Construction, Ship Alteration, and 
                               Ship Repair



1317.7001  Solicitation provisions and contract clauses.

    (a)(1) The contracting officer shall insert the following clauses in 
sealed bid fixed-price solicitations and contracts for ship 
construction, ship alteration, and ship repair.
    (i) Inspection and Manner of Doing Work, 1352.217-90.
    (ii) Delivery of the Vessel to the Contractor, 1352.217-91.
    (iii) Performance, 1352.217-92.
    (iv) Delays, 1352.217-93.
    (v) Minimization of Delay Due to Government Furnished Property, 
1352.217-94.
    (vi) Additional Provisions Relating to Government Property, 
1352.217-95.
    (vii) Liability and Insurance, 1352.217-96.
    (viii) Title, 1352.217-97.
    (ix) Discharge of Liens, 1352.217-98.
    (x) Department of Labor Occupational Safety and Health Standards for 
Ship Repairing, 1352.217-99.
    (xi) Regulations Governing Asbestos Work, 1352.217-100.
    (xii) Complete and Final Equitable Adjustments, 1352.217-101.
    (xiii) Government Review, Comment, Acceptance, and Approval, 
1352.217-102.

[[Page 599]]

    (xiv) Access to the Vessel, 1352.217-103.
    (xv) Documentation of Requests for Equitable Adjustment, 1352.217-
104.
    (xvi) Change Proposals, 1352.217-105.
    (xvii) Lay Days, 1352.217-106.
    (xviii) Changes--Ship Repair, 1352.217-107.
    (xix) Default--Ship Repair, 1352.217-108.
    (2) Unless inappropriate due to contract type, the contracting 
officer shall insert the clauses listed above in negotiated 
solicitations and contracts for ship construction, ship alteration, and 
ship repair.
    (b) The contracting officer shall insert a clause substantially the 
same as the clause at 1352.217-109, Insurance Requirements, in 
solicitations and contracts for ship construction, ship alteration, and 
ship repair, unless the contracting officer determines that the 
contract, or job order, requires work on parts of a vessel only and the 
work is to be performed at a plant other than the site of the vessel.
    (c) The contracting officer shall insert the clause at 1352.217-110, 
Guarantees, unless the contracting officer determines that its use would 
be inappropriate under the circumstances.
    (d) The contracting officer shall insert the clause at 1352.217-111, 
Temporary Services, in solicitations and contracts for ship 
construction, ship alteration, and ship repair, unless the contracting 
officer determines that its use would be inappropriate under the 
circumstances.
    (e) The contracting officer shall insert the provision at 1352.217-
112, Self-Insurance Information, in solicitations and contracts for ship 
construction, ship alteration, and ship repair, when the contracting 
officer determines that it is appropriate to allow offerors the 
opportunity to self-insure for any or all of the risks set forth in the 
applicable insurance clauses of the contract.
[52 FR 3807, Feb. 6, 1987]

[[Page 600]]



                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS





PART 1319--SMALL BUSINESS AND SMALL DISADVANTAGED BUSINESS CONCERNS--Table of Contents




                        Subpart 1319.2--Policies

Sec.
1319.202-2  Locating small business sources.

      Subpart 1319.7--Subcontracting With Small Business and Small 
               Disadvantaged Business Concerns [Reserved]

    Subpart 1319.70--Contracting Opportunities for Women-Owned Small 
                               Businesses

1319.7002  Source identification and solicitation.
1319.7003  Subcontracting opportunities.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.



                        Subpart 1319.2--Policies



1319.202-2  Locating small business sources.

    (b) The contracting officer shall send a copy of the requisition 
form for all procurement actions expected to exceed $500,000 ($1,000,000 
for construction) to the Office of Small and Disadvantaged Business 
Utilization, as promptly after receipt as possible. The Office of Small 
and Disadvantaged Business Utilization shall review the procurement 
actions and recommend action to the contracting officer. Orders under 
GSA schedule contracts, orders under Department or Government-wide 
indefinite delivery contracts, or actions within the scope of the 
changes, value engineering, or similar contract clauses are exempt from 
the requirements of this subsection.
[50 FR 19364, May 8, 1985, and 51 FR 1377, Jan. 13, 1986]



      Subpart 1319.7--Subcontracting With Small Business and Small 
               Disadvantage Business Concerns  [Reserved]



    Subpart 1319.70--Contracting Opportunities for Women-Owned Small 
                               Businesses

    Source:  51 FR 15331, Apr. 23, 1986, unless otherwise noted.



1319.7002  Source identification and solicitation.

    (a) The contracting officer shall include women-owned small 
businesses on the mailing list for each solicitation which is expected 
to result in an award in excess of the small purchase dollar threshold 
whenever there are women-owned small businesses known to be potential 
suppliers.
[51 FR 15331, Apr. 23, 1986, as amended at 60 FR 47310, Sept. 12, 1995]



1319.7003  Subcontracting opportunities.

    (a) Contracting officers shall provide assistance to prime 
contractors to identify potential women-owned small businesses. Such 
assistance is intended to aid prime contractors in placing a fair 
proportion of subcontracts with women-owned small businesses.
    (b) The contracting officer shall insert the clause at 1352.219-1, 
Women-Owned Small Business Sources, in solicitations and contracts where 
the clause prescribed by FAR 19.708(b) is required (see FAR 52.219-9).



PARTS 1322-1325 [RESERVED]




[[Page 601]]



             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS





PART 1331 [RESERVED]






PART 1332--CONTRACT FINANCING--Table of Contents




                         Subpart 1332.1--General

Sec.
1332.102  Description of contract financing methods.

                        Subpart 1332.4 [Reserved]

                        Subpart 1332.6 [Reserved]

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.

    Source:  49 FR 12963, Mar. 30, 1984, unless otherwise noted.



                         Subpart 1332.1--General



1332.102  Description of contract financing methods.

    (e)(2) Progress payments based on a percentage or stage of 
completion are authorized for use as a payment method under Department 
contracts and subcontracts for construction, alteration, repair, ship 
construction, ship alteration, and ship repair. For all other contracts, 
progress payments shall be based on costs except when the head of the 
contracting office determines that progress payments based on costs 
cannot be practically employed. In those cases, progress payments based 
on a percentage or stage of completion may be authorized when the head 
of the contracting office also determines that adequate safeguards are 
provided for the administration of those payments.



                        Subpart 1332.4 [Reserved]



                        Subpart 1332.6 [Reserved]



PART 1333--PROTESTS, DISPUTES, AND APPEALS--Table of Contents




                        Subpart 1333.1--Protests

Sec.
1333.103  Protests to the agency.
1333.104  Protests to GAO.
1333.105  Protests to GSBCA.
1333.106  Solicitation provision and contract clause.

                  Subpart 1333.2--Disputes and Appeals

1333.213  Obligation to continue performance.

          Subpart 1333.70--Department Board of Contract Appeals

1333.70-1  Department Board of Contract Appeals.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.

    Source:  51 FR 15331, Apr. 23, 1986, unless otherwise noted.



                        Subpart 1333.1--Protests



1333.103  Protests to the agency.

    (a) Protests must be received within ten work days after the basis 
for protest is known or should have been known unless good cause is 
shown to extend the time limit. However, protests based upon alleged 
improprieties in any type of solicitation which are apparent prior to 
bid opening or the closing time for receipt of initial proposals shall 
be filed prior to bid opening or the closing time for receipt of initial 
proposals. Unless the time limit for receiving the protest is extended 
for

[[Page 602]]

good cause, a protest to the contracting activity which is received 
after the time limit will not be considered. When a timely protest is 
filed only with the contracting activity, the contracting officer shall 
take prompt action towards resolution after consulting with the AGC, and 
notify the protestor in writing of the action taken.
    (b) When a protest is filed only with the contracting activity 
before award, an award shall not be made until the matter is resolved 
unless the head of the contracting office makes the determination 
prescribed in FAR 33.103(a).
    (c) When a protest is filed only with the contracting activity after 
award, the contracting officer need not notify the contractor if the 
protest can be promptly resolved. If it appears likely that the award 
may be invalidated or that a protest will be filed with the GAO or the 
GSBCA, the contracting officer should promptly notify the contractor in 
writing and consider suspending contract performance.



1333.104  Protests to GAO.

    (a)(1) General. A protestor shall furnish a copy of its complete 
protest to the contracting officer designated in the solicitation and a 
copy of its complete protest to the Contract Law Division of the Office 
of the Assistant General Counsel for Finance and Litigation, no later 
than one day after the protest is filed with the GAO. The envelope 
containing the complete protest shall be clearly marked ``GAO Protest''.
    (2) The GAO report shall be assembled and organized by the 
contracting office in accordance with rule 4(d) of the GSBCA Rules of 
Procedure (48 CFR part 6101) except where rule 4(d) may conflict with 
GAO procedures.
    (b) Protests before award. When the contracting activity has 
received notice of a protest filed directly with GAO, a contract may not 
be awarded prior to a GAO decision on the protest, unless the Head of 
the Contracting Activity makes the written finding prescribed in FAR 
33.104 (b)(1) after consulting with the AGC. The head of the contracting 
office shall notify the AGC when the written finding has been executed 
so that the AGC can notify GAO. The contracting activity is not 
authorized to award the affected contract until the AGC has notified GAO 
of the written finding.
    (c) Protests after award. When the contracting activity receives 
notice of a protest filed directly with GAO within 10 calendar days 
after contract award, the contracting officer shall immediately suspend 
performance pending a GAO decision on the protest or terminate the 
awarded contract, unless the Head of the Contracting Activity makes the 
written finding prescribed in FAR 33.104 (c)(2) after consulting with 
the AGC. The head of the contracting office shall notify the AGC when 
the written finding has been executed so that the AGC can notify GAO. 
The contracting activity is not authorized to continue contract 
performance until the AGC has notified GAO of the written finding.
[51 FR 15331, Apr. 23, 1986, as amended at 60 FR 47310, Sept. 12, 1995]



1333.105  Protests to GSBCA.

    (a)(1) A protestor shall furnish a copy of its complete protest to 
the contracting officer designated in the solicitation and a copy of its 
complete protest to the Contract Law Division of the Office of the 
Assistant General Counsel for Finance and Litigation, on the same day 
the protest is filed with the GSBCA. The envelope containing the 
complete protest shall be clearly marked ``GSBCA Protest''.
[51 FR 15331, Apr. 23, 1986, as amended at 60 FR 47310, Sept. 12, 1995]



1333.106  Solicitation provision and contract clause.

    (a) The contracting officer shall insert the provision at 1352.233-
2, Service of Protest (JAN 1985) (Deviation FAR 52.233-2), in lieu of 
the provision at FAR 52.233-2 in solicitations for other than small 
purchases.



                  Subpart 1333.2--Disputes and Appeals



1333.213  Obligation to continue performance.

    (a) The contracting officer may use Alternate I to the clause at FAR 
52.233-1, Disputes, only after the Head of the

[[Page 603]]

Contracting Activity has determined in writing that--
    (1) Continued performance is necessary pending resolution of any 
claim arising under or relating to the contract because of unusual 
circumstances which make continued performance essential to the public 
health or welfare;
    (2) Financing is or will be available for the continued performance; 
and
    (3) The Government's interest is or will be properly secured.



          Subpart 1333.70--Department Board of Contract Appeals



1333.70-1  Department Board of Contract Appeals.

    The General Services Administration (GSA) Board of Contract Appeals 
serves as the Board of Contract Appeals for the Department.
[49 FR 12964, Mar. 30, 1984]

[[Page 604]]



             SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING





PART 1334 [RESERVED]






PART 1336--CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS--Table of Contents




     Subpart 1336.2--Special Aspects of Contracting for Construction

Sec.
1336.209  Construction contracts with architect-engineer firms.

               Subpart 1336.6--Architect-Engineer Services

1336.602-5  Short selection processes for contracts not to exceed 
          $10,000.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.

    Source:  49 FR 12964, Mar. 30, 1984, unless otherwise noted.



     Subpart 1336.2--Special Aspects of Contracting for Construction



1336.209  Construction contracts with architect-engineer firms.

    The head of the contracting office is delegated the authority to 
approve the exceptional circumstance of awarding a contract for 
construction of a project to the firm that designed the project. Any 
approval of this type of award must be justified in writing and signed 
by the head of the contracting office.



               Subpart 1336.6--Architect-Engineer Services



1336.602-5  Short selection processes for contracts not to exceed $10,000.

    Both short selection processes prescribed in FAR 36.602-5 may be 
used for contracts not to exceed $10,000. However, in either case the 
contracting officer shall review the report, approve it and commence 
negotiations or return it for appropriate revision.



PART 1337 [RESERVED]




[[Page 605]]



                    SUBCHAPTER G--CONTRACT MANAGEMENT





PART 1342--CONTRACT ADMINISTRATION--Table of Contents




    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.



 Subpart 1342.1--Interagency Contract Administration and Audit Services



1342.102-70  Post award audit reviews.

    (a) Generally, the final invoice shall not be approved until a 
close-out audit has been performed and all outstanding issues have been 
negotiated or resolved on the following types of contracts of $100,000 
and above:
    (1) Cost-reimbursement type contracts;
    (2) The cost-reimbursement portion of fixed-price contracts;
    (3) Letter contracts which provide for reimbursement of costs;
    (4) Time and materials contracts; and
    (5) Labor-hour contracts.
    (b) Even though the $100,000 postaward audit threshold generally 
applies, an audit may be requested regardless of the dollar amount when 
the contracting officer determines that an audit is justified under one 
of the following circumstances:
    (1) There is some evidence of fraud or waste;
    (2) The contractor's performance under the contract has been 
questionable;
    (3) The contractor had a high incidence of unallowable costs under a 
previous contract;
    (4) The contract is with a newly established firm, or a firm which 
has just begun dealing with the Government.
[49 FR 12965, Mar. 30, 1984; as amended at 60 FR 47310, Sept. 12, 1995]



PART 1345 [RESERVED]






PART 1349--TERMINATION OF CONTRACTS--Table of Contents




Sec.
1349.001  Definitions.

                 Subpart 1349.4--Termination for Default

1349.402-7  Other damages.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Sec'y of 
Commerce in Dept. Org. Order 10-5 and Dept. Adm. Order 208-2.



1349.001  Definitions.

    (a) Administrative costs, as used in this part, means those costs 
other than excess costs, incurred by the Government as a result of the 
contractor's default. Administrative costs include but are not limited 
to:
    (1) Salaries and fringe benefits paid to Government employees who 
are assigned to a work activity (e.g., reprocurement activities) as a 
result of the default;
    (2) Preaward survey expenses incurred in qualifying reprocurement 
contractors; and
    (3) Costs incurred in printing and distributing the reprocurement 
solicitation.
    (b) Excess costs, as used in this part, means any costs, other than 
administrative costs, incurred by the Government in reprocuring similar 
supplies or services or performing similar services as a result of the 
contractor's default.
[51 FR 15332, Apr. 23, 1986]



                 Subpart 1349.4--Termination for Default



1349.402-7  Other damages.

    (a) The contracting officer may recover administrative costs under 
the default clause when it is in the best interest of the Government. A 
contracting officer's decision to recover administrative costs must 
balance the expected cost to the Government of documenting and 
supporting the assessment with the expected recovery amount.

[[Page 606]]

    (b) Documents used to support an assessment of administrative costs 
must clearly demonstrate that the added costs incurred by the Government 
were a direct result of the default.
    (1) To support administrative labor costs, the contracting officer 
should keep a record of:
    (i) Name, position, and organization of each employee performing 
work activities as a consequence of the default;
    (ii) Dates of work and time spent by each employee on the 
repurchase;
    (iii) Specific tasks performed (e.g., solicitation preparation, 
clerical);
    (iv) Hourly rates of pay (straight time or overtime); and
    (v) Applicable fringe benefits.
    (2) Travel vouchers, invoices, printing requisitions, and other 
appropriate evidence of expenditures may be used to support other 
administrative costs (e.g., travel, per diem, printing and distribution 
of the repurchase contract).
    (c) If assessment of administrative costs is considered appropriate 
after review by the AGC, the contracting officer shall make a written 
demand on the contractor for administrative costs. The written demand 
shall describe the basis for the assessment and the cost computations. 
The same demand letter may be used to assess administrative costs and 
any excess costs. If the contractor fails to make payment after 
receiving a contracting officer's final decision, the contracting 
officer shall follow the procedures in subpart 1332.6 and FAR Subpart 
32.6 to collect the amount owed the Government.
    (d) The recovery of excess or administrative costs does not preclude 
the Government from exercising other rights or remedies which it may 
have by law or under the terminated contract.
[51 FR 15332, Apr. 23, 1986]

[[Page 607]]



                     SUBCHAPTER H--CLAUSES AND FORMS





PART 1352--SOLICITATION PROVISIONS AND CONTRACT CLAUSES--Table of Contents




                         Subpart 1352.0--General

Sec.
1352.000  Scope of part.
1352.001  General policy.

      Subpart 1352.1--Instructions for Using Provisions and Clauses

1352.100  Incorporation by reference.

             Subpart 1352.2--Texts of Provisions and Clauses

1352.217-90  Inspection and manner of doing work.
1352.217-91  Delivery of vessel to the contractor.
1352.217-92  Performance.
1352.217-93  Delays.
1352.217-94  Minimization of delay due to Government furnished property.
1352.217-95  Additional provisions relating to Government property.
1352.217-96  Liability and insurance.
1352.217-97  Title.
1352.217-98  Discharge of liens.
1352.217-99  Department of Labor occupational safety and health 
          standards for ship repairing.
1352.217-100  Regulations governing asbestos work.
1352.217-101  Complete and final equitable adjustments.
1352.217-102  Government review, comment, acceptance, and approval.
1352.217-103  Access to the vessel(s).
1352.217-104  Documentation of requests for equitable adjustment.
1352.217-105  Change proposals.
1352.217-106  Lay days.
1352.217-107  Changes--ship repair.
1325.217-108  Default--ship repair.
1352.217-109  Insurance requirements.
1352.217-110  Guarantees.
1352.217-111  Temporary services.
1352.217-112  Self-insurance information.
1352.219-1  Women-owned small business sources.
1352.233-2  Service of protest.

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2).

    Source:  49 FR 12965, Mar. 30, 1984, unless otherwise noted.



                         Subpart 1352.0--General



1352.000  Scope of part.

    This part implements and supplements FAR Part 52 by prescribing 
specific modifications, alterations, and deviations to FAR solicitation 
provisions and contract clauses for Department-wide use.



1352.001  General policy.

    The Department's policy is to use the FAR and CAR prescribed 
solicitation provisions and contract clauses unless specific authority 
for deviations has been obtained. (See 1301.4 for authority to deviate.) 
The use of uniform solicitation provisions and contract clauses should: 
provide a less burdensome way for potential contractors to respond to 
the Government's request for information concerning the evaluation of 
bids and proposals; expedite solicitation and contract preparation; and 
facilitate contract negotiation, administration and review. Each 
solicitation which incorporates contract clauses or solicitation 
provisions which deviate from those prescribed by the FAR and the CAR 
must be submitted to the Office of Procurement and Federal Assistance 
for prior review. The Office of Procurement and Federal Assistance will 
coordinate requests for approval of these solicitations by the Office of 
Management and Budget, in accordance with the Paperwork Reduction Act of 
1980 and 5 CFR part 1320.



      Subpart 1352.1--Instructions for Using Provisions and Clauses



1352.100  Incorporation by reference.

    Contracting officers within the Department shall incorporate 
solicitation provisions and contract clauses by reference in 
solicitations and contracts to the maximum extent provided by applicable 
law and regulation. Incorporation by reference is the listing only by 
title, regulatory citation, and date of the provision or clause rather 
than the full text. The full text of the referenced solicitation 
provision or contract clause is contained in the Code of Federal

[[Page 608]]

Regulations (CFR); chapter 1 of title 48 for FAR provisions and clauses; 
and chapter 13 of title 48 for CAR provisions and clauses.



             Subpart 1352.2--Texts of Provisions and Clauses

    Source:  52 FR 3808, Feb. 6, 1987, unless otherwise noted.



1352.217-90  Inspection and manner of doing work.

    As prescribed in 1317.7001(a), insert the following clause:

    Inspection and Manner of Doing Work (CAR 1352.217-90) (Jan 1987)

    (a) All work and material shall be subject to the approval of the 
Contracting Officer or his duly authorized representative. Work shall be 
performed in accordance with the plans and specifications of this 
contract as modified by any contract modification.
    (b) Unless otherwise specifically provided for in the contract, all 
operational practices of the Contractor and all workmanship and 
material, equipment and articles used in the performance of work shall 
be in accordance with American Bureau of Shipping Rules for Building and 
Classing Steel Vessels, U.S. Coast Guard Marine Engineering Regulations 
and Material Specifications (Subchapter F 46 CFR), U.S. Coast Guard 
Electrical Engineering Regulations (Subchapter J 46 CFR) (APR 1982), and 
U.S.P.H.S., Handbook on Sanitation in Vessel Construction, in effect at 
the time of the Contractor's submission of bid (or acceptance of the 
contract, if negotiated), and the best commercial maritime practices, 
except where military specifications are specified, in which case such 
standards of material and workmanship shall be followed.
    (c) All material and workmanship shall be subject to inspection and 
test at all times during the Contractor's performance of the work to 
determine their quality and suitability for the purpose intended and 
compliance with the contract. In case any material or workmanship 
furnished by the Contractor is found to be defective prior to redelivery 
of the vessel, or not in accordanoe with the requirements of the 
contract, the Government shall have the right prior to redelivery of the 
vessel to reject such material or workmanship, and to require its 
correction or replacement by the Contractor at the Contractor's cost and 
expense. This Government right is in addition to its rights under any 
Guarantee clause in this contract. If the Contractor fails to proceed 
promptly with the replacement or correction of such material or 
workmanship, as required by the Contracting Officer, the Government may, 
by contract or otherwise, replace or correct such material or 
workmanship and charge to the Contractor the excess cost to the 
Government. The Contractor shall provide and maintain an inspection 
system acceptable to the Government covering the work specified in the 
contract. Records of all inspection work by the Contractor shall be kept 
complete and available to the Government during the performance of the 
contract and for a period of 2 years after delivery of the vessel to the 
Government.
    (d) No welding, including tack welding and brazing, shall be 
permitted in connection with repairs, completions, alterations, or 
addition to hulls, machinery or components of vessels unless the welder 
is at the time, qualified to the standards established by the United 
States Coast Guard, the American Bureau of Shipping, or the Department 
of the Navy. The welder's qualifications shall be appropriate for the 
particular service application, filler material type, position of 
welding, and welding process involved in the work being undertaken. A 
welder may be required to requalify if the Contracting Officer believes 
there is a reasonable doubt concerning the welder's ability. Welder's 
qualifications for this purpose shall be outlined in ``Marine 
Engineering Regulations'' of the United States Coast Guard. When a 
welding process other than manual shielded arc is proposed or required, 
the contractor or fabricator shall submit procedure qualification tests 
for approval prior to production welding. Procedure qualification tests 
shall be conducted in accordance with the requirements of the ``Marine 
Engineering Regulations'' of the United States Coast Guard.
    (e) The Contractor shall exercise reasonable care to protect the 
vessel from fire, and the Contractor shall maintain a reasonable system 
of inspection over the activities of welders, burners, riveters, 
painters, plumbers and similar workers, particularly where such 
activities are undertaken in the vicinity of the vessel's magazine, fuel 
oil tanks, or storerooms containing flammable material. A reasonable 
number of hose lines shall be maintained by the Contractor ready for 
immediate use on the vessel at all times while the vessel is berthed 
alongside the Contractor's pier or in drydock or on a marine railway. 
All tanks or bilge areas under alteration or repair shall be cleaned, 
washed, and steamed out or otherwise made safe by the Contractor if and 
to the extent necessary as required by good marine practice or by 
current OSHA Regulations. The Contracting Officer's Technical 
Representative (COTR) shall be furnished with a ``gas free'' or ``safe 
for hot work'' or ``safe for men'' certificate before any hot work or 
entry is done. Unless otherwise provided in this contract, the 
Contractor shall at all times maintain a reasonable fire watch about the 
vessel, including a

[[Page 609]]

fire watch on the vessel while work is being performed thereon.
    (f) The Contractor shall place proper safeguards and/or effect such 
safety precautions as necessary, including suitable and sufficient 
lighting, for the prevention of accidents or injury to persons or 
property during the prosecution of work under this contract and/or from 
time of receipt of the vessel until acceptance by the Government of the 
work performed.
    (g) Except as otherwise provided in this contract, when the vessel 
is in the custody of the contractor or in drydock or on a marine railway 
and the temperature becomes as low as 35 degrees Fahrenheit, the 
Contractor shall keep all pipelines, fixtures, traps, tanks, and other 
receptacles on the vessel drained to avoid damage from freezing, or if 
this is not practicable, the vessel shall be kept heated to prevent such 
damage. The vessel's stern tube and propeller hubs shall be protected 
from frost damage by applied heat through the use of a salamander or 
other proper means, as approved by the COTR.
    (h) Whenever practicable, the work shall be performed in a manner 
which does not interfere with the berthing and messing of personnel 
attached to the vessel. The Contractor shall ensure that assigned 
personnel have access to the vessel at all times. It is understood that 
such personnel will not interfere with the work or the Contractor's 
workers.
    (i) The Government does not guarantee the correctness of the 
dimensions, sizes, and shapes given in any sketches, drawings, plans or 
specifications prepared or furnished by the Government. The Contractor 
shall be responsible for the correctness of the shape, sizes and 
dimensions of parts to be furnished hereunder, other than those 
furnished by the Government.
    (j) The Contractor shall at all times keep the site of the work on 
the vessel free from accumulation of waste material or rubbish caused by 
Contractor employees or the work, and at the completion of the work 
shall remove all rubbish from and about the site of the work and shall 
leave the work and its immediate vicinity ``broom clean'' unless more 
exactly specified in this contract.
    (k) While in drydock or on a marine railway, the Contractor shall be 
responsible for the closing before the end of working hours, of all 
valves and openings upon which work is being done by its workers when 
such closing is practicable. The Contractor shall keep the COTR 
cognizant of the closure status of all valves and openings upon which 
the Contractor's workers have been working.
    (l) Without additional expense to the Government, the Contractor 
shall employ specialty subcontractors where required by the 
specifications or when necessary for satisfactory performance of the 
work.
    (m) When requested by the COTR, the Contractor shall notify the COTR 
in advance:
    (i) Prior to starting inspections or tests; and
    (ii) When supplies will be ready for Government inspection.
    (n) When advance notification is requested, the authorized COTR 
shall specify the period and method of notification.

                             (End of clause)



1352.217-91  Delivery of vessel to the contractor.

    As prescribed in 1317.7001(a), insert the following clause:

    Delivery of Vessel to the Contractor (CAR 1352.217-91) (Jan 1987)

    (a) The Government shall deliver the vessel to the Contractor at the 
location specified in the contract.
    (b) If the Contractor's plant is specified, it shall be understood 
to mean the fairway of the plant. The Contractor shall provide necessary 
tugs and pilot services to move the vessel from the fairway to the pier 
or dock and, upon completion of all work, from the pier or dock to the 
fairway of the plant.
    (c) While the vessel is in the possession of the Contractor, any 
necessary movement of the vessel incidental to the work specified in the 
contract shall be furnished by the Contractor without additional charge 
to the Government.

                             (End of clause)



1352.217-92  Performance.

    As prescribed in 1317.7001(a), insert the following clause:

                Performance (CAR 1352.217-92) (Jan 1987)

    (a) Upon the issuance of the contract, the Contractor shall promptly 
commence the work specified in any plans and specifications made a part 
of the contract, and shall diligently prosecute the work to completion. 
The Contractor shall not commence work until the contract has been 
issued.
    (b) The Government shall deliver the vessel described in the 
contract at such time and location as may be specified in the contract. 
Upon completion of the work, the Government shall accept delivery of the 
vessel at such time and location as may be specified in the contract.
    (c) Without additional charge to the Government, and without 
specific requirement in the contract, the Contractor shall:
    (1) Make available at the plant to personnel of the vessel while in 
drydock or on a marine railway, toilet and similar facilities acceptable 
to the Contracting Officer as adequate in number and sanitary standards;

[[Page 610]]

    (2) Supply and maintain, in such condition as the Contracting 
Officer may reasonably require, suitable brows and gangways from the 
pier, drydock or marine railway to the vessel;
    (3) Treat salvage, scrap, or other ship's material of the Government 
resulting from performance of the work as items of Government furnished 
property in accordance with the Government Property clause;
    (4) Perform, or pay the cost of, any repair, reconditioning or 
replacement made necessary as the result of the use by the Contractor of 
any of the vessel's machinery, equipment or fittings, including, but not 
limited to, winches, pumps, riggings, or pipe lines; and
    (5) Furnish suitable offices, office equipment and telephones at or 
near the site of the work as the Contracting Officer reasonably requires 
for himself and his staff.
    (d) Except as otherwise provided in the contract, the Contractor 
shall furnish all necessary material, labor, services, equipment, 
supplies, power, accessories, facilities, and other things and services 
necessary for accomplishing the work, subject to Government rights under 
the Government Property clause.
    (e) The Contractor shall conduct dock and sea trials of the vessel 
as required by the contract. Unless otherwise expressly provided in the 
contract, during the conduct of these trials the vessel shall be under 
the control of the vessel's commander and crew with representatives of 
the Contractor and the Government on board to determine whether or not 
the work done by the Contractor has been satisfactorily performed. Dock 
and sea trials not speoified which the Contractor requires for his own 
benefit shall not be undertaken by the Contractor without prior notice 
to and approval of the Contracting Officer; any such dock or sea trial 
shall be conducted at the risk and expense of the Contractor. The 
Contractor shall provide and install all fittings and appliances which 
may be necessary for the dock and sea trials, to enable the 
representatives of the Government to determine whether the requirements 
of the contract plans and specifications have been met. The Contractor 
shall also be responsible for the care, installation and removal of any 
instruments and apparatus furnished by the Government for such trials.

                             (End of clause)



1352.217-93  Delays.

    As prescribed in 1317.7001(a), insert the following clause:

                   Delays (CAR 1352.217-93) (Jan 1987)

    When during the performance of this contract the Contractor is 
required to delay the work on a vessel temporarily, due to orders or 
actions of the Government respecting stoppage of work to permit shifting 
the vessel, stoppage of hot work to permit bunkering, fueling, stoppage 
of work due to embarking or debarking passengers and loading or 
discharging cargo, and the Contractor is not given sufficient advance 
notice or is otherwise unable to avoid incurring additional costs on 
account thereof, an equitable adjustment may be made in the contract 
price pursuant to the Changes clause.

                             (End of clause)



1352.217-94  Minimization of delay due to Government furnished property.

    As prescribed in 1317.7001(a), insert the following clause:

    Minimization of Delay Due to Government Furnished Property (CAR 
                         1352.217-94) (Jan 1987)

    (a) In order to assure timely delivery of the vessel under this 
contract, it is imperative that delay in delivery of such vessel 
resulting from late, damaged, or unsuitable Government furnished 
property be held to an absolute minimum. In order to achieve 
minimization of delay it is agreed that:
    (1) Subject to adjustment as provided in paragraph (b) of this 
clause, the Government shall deliver each item of Government furnished 
property to the Contractor on or before the date specified in the 
contract or, if later, in sufficient time for the contractor to deliver 
the vessel in accordance with the delivery schedule specified elsewhere.
    (2) The Government may forego furnishing any item of Government 
property to the Contractor. In that event, the Contractor shall prepare 
the vessel in terms of piping, wiring, structure, foundation, 
ventilation, and any other preinstallation requirements of the item, so 
that the work on the vessel may continue without delay and disruption 
resulting from the absence of the item. If the Government does not 
furnish an item designated as Government furnished property, the parties 
may be entitled to an equitable adjustment in the contract price, in 
accordance with the Changes clause for eliminating the requirement to 
install the Government property item. But, notwithstanding any other 
clause of this contract, an adjustment shall not be made in the delivery 
schedule of any vessel if the Government chooses not to furnish the item 
on or before the delivery date of the item. If the Government 
subsequently desires the Contractor to install the item prior to 
delivery of the vessel, a contract modification shall be executed which 
takes into account any increase in cost or performance time resulting 
from the installation.
    (b) If the delivery date for the vessel is extended for any reason, 
the latest date for

[[Page 611]]

which the Government must deliver items of Government property shall be 
deemed to be extended by an equal number of days unless (i) the 
Contracting Officer agrees in writing that earlier delivery of the items 
is required, in which case some or all of the Government property shall 
be extended as agreed rather than on a day-for-day basis, or (ii) a 
Government property item was the exclusive cause for the extension of 
the delivery date of the vessel in which case the latest date by which 
the Government must deliver the item shall not be deemed to be extended 
unless the parties agree otherwise.
    (c) The delivery or performance dates for the supplies or services 
to be furnished by the Contractor under this contract are based upon the 
expectation that Government furnished property suitable for use (except 
for such property furnished ``as is'') will be delivered to the 
Contractor at the time stated in the specification or, if not so stated, 
in sufficient time to enable the Contractor to meet such delivery or 
performance dates. If the Government furnished property is not delivered 
to the Contractor by such time and the Contractor makes a timely written 
request, the Contracting Officer shall determine if an equitable 
adjustment is appropriate. If determined appropriate, the Contracting 
Officer shall equitably adjust the delivery or performance date, the 
specifications, the price, or any other contractual provision affected 
by any such delay, in accordance with the Changes clause.
    (d) The Government Property and Minimization of Delay Due to 
Government Furnished Property clauses contain exclusive remedies. The 
Government shall not be liable to suit for breach of contract by reason 
of any delay in delivery of Government furnished property or delivery of 
such property in a condition not suitable for its intended use.

                             (End of clause)



1352.217-95  Additional provisions relating to Government property.

    As prescribed in 1317.7001(a), insert the following clause:

Additional Provisions Relating to Government Property (CAR 1352.217-95) 
                               (Jan 1987)

    (a) Notwithstanding any requirements to the contrary for the 
furnishing of material by the Government which may appear in plans, 
drawings, or other data, the Government shall furnish only the material 
specifically listed in the specifications as Government furnished 
property. Any material required for the performance of the contract 
which does not appear in the specifications as Government furnished 
shall be furnished by the Contractor.
    (b) The Contracting Officer may increase the amount of material to 
be furnished by the Government and the contract shall be equitably 
adjusted in accordance with the Government Property clause.
    (c) Unless otherwise specifically directed by the Contracting 
Officer, nonreusable crates and other nonreusable packaging in which 
Government material is delivered to the Contractor shall become the 
property of the Contractor upon removal of the packaged or crated 
material.
    (d) Any packaging in preparation for delivery or for other disposal 
of Government property by the Contractor at the direction or 
authorization of the Contracting Officer pursuant to paragraph (i) of 
the Government Property clause shall be provided for by change order and 
an appropriate adjustment shall be made in the contract price in 
accordance with the Changes clause.
    (e) The vessel, its equipment, movable stores, cargo and other 
ship's material are not designated Government furnished property under 
the Government Property clause.

                             (End of clause)



1352.217-96  Liability and insurance.

    As prescribed in 1317.7001(a), insert the following clause:

          Liability and Insurance (CAR 1352.217-96) (Jan 1987)

    (a) The Contractor shall exercise reasonable care and use its best 
efforts to prevent accidents, injury or damage to all employees, persons 
and property, in and about the work, and to the vessel or part thereof 
upon which work is done.
    (b) The Contractor shall be responsible for and make good at its own 
cost and expense any and all loss of or damage of whatsoever nature to 
the vessel (or part thereof), its equipment, movable stores and cargo, 
and Government owned material and equipment for the repair, completion, 
alteration of or addition to the vessel in the possession of the 
Contractor, whether at the plant or elsewhere, arising or growing out of 
the performance of the work, except where the Contractor can 
affirmatively show that such loss or damage was due to causes beyond the 
Contractor's control, was proximately caused by the fault or negligence 
of agents or employees of the Government, or which loss or damage the 
Contractor by exercise of reasonable care was unable to prevent. 
However, the Contractor shall not be responsible for any such loss or 
damage discovered after redelivery of the vessel unless (i) the loss or 
damage is discovered within 90 days after redelivery of the vessel and 
(ii) loss or damage is affirmatively shown to be the result of the fault 
or negligence of the Contractor. To induce the Contractor to perform the 
work for

[[Page 612]]

the compensation provided, it is specifically agreed that the 
Contractor's aggregate liability on account of loss of or damage to the 
vessel (or part thereof), its equipment, movable stores and cargo and 
Government owned materials and equipment shall in no event exceed the 
sum of $300,000. As to the Contractor, the Government assumes the risk 
of loss or damage to the Government-owned vessel (or part thereof), its 
equipment, movable stores and cargo and said Government-owned materials 
and equipment in excess of $300,000. This assumption of risk includes 
but is not limited to loss or damage from negligence of whatsoever 
degree of the Contractor's servants, employees, agents or subcontractors 
but specifically excludes loss or damage from willful misconduct or lack 
of good faith on the part of the Contractor's directors, officers and 
any of its managers, superintendents or other equivalent representatives 
who have supervision or direction of (i) all or substantially all of the 
Contractor's business, or (ii) all or substantially all of the 
Contractor's operation at any one plant. However, as to such risk 
assumed and borne by the Government, the Government shall be subrogated 
to any claim, demand or cause of action against third persons which 
exists in favor of the Contractor, and the contractor shall, if 
required, execute a formal assignment or transfer of claims, demands or 
causes of action. Nothing contained in this paragraph shall create or 
give rise to any right, privilege or power in any person except the 
Contractor, nor shall any person (except the Contractor) be or become 
entitled thereby to proceed directly against the Government, or join the 
Government as a co-defendent in any action against the Contractor 
brought to determine the Contractor's liability, or for any other 
purpose.
    (c) The Contractor indemnifies and holds harmless the Government, 
its agencies and instrumentalities, and the vessel against all suits, 
actions, claims, costs or demands (including without limitation, suits, 
actions, claims, costs or demands resulting from death, personal injury 
and property damage) to which the Government, its agencies and 
instrumentalities, or the vessel may be subject or put by reason of 
damage or injury (including death) to the property or person of any one 
other than the Government, its agencies, instrumentalities and 
personnel, or the vessel arising or resulting in whole or in part from 
the fault, negligence, wrongful act or wrongful omission of the 
Contractor, or any subcontractor, its or their servants, agents or 
employees; provided that the Contractor's obligation to indemnify under 
this paragraph (c) shall not exceed the sum of $300,000 on account of 
any one accident or occurrence in respect of any one vessel. Such 
indemnity shall include, without limitation, suits, actions, claims, 
costs or demands of any kind whatsoever, resulting from death, personal 
injury or property damage occurring during the period of performance of 
work on the vessel or within 90 days after redelivery of the vessel. 
With respect to any such suits, actions, claims, costs or demands 
resulting from death, personal injury or property damage occurring after 
the expiration of such period, the rights and liabilities of the 
Government and the Contractor shall be as determined by other provisions 
of this contract and by law; provided that such indemnity shall apply to 
death occurring after such period which results from any personal injury 
received during the period covered by the Contractor's indemnity as 
provided herein.
    (d) The Contractor shall, at its own expense, procure, and 
thereafter maintain such casualty, accident and liability insurance, in 
such forms and amounts as may be approved by the Contracting Officer, 
insuring the performance of its obligations under paragraph (c) of this 
clause. In addition, the Contractor shall at its own expense procure and 
thereafter maintain such ship repairer's legal liability insurance as 
may be necessary to insure the Contractor against its liability as ship 
repairer in the amount of $300,000, or the value of the vessel as 
determined by the Contracting Officer, whichever is the lesser, with 
respect to each vessel on which work is performed. The Contractor shall 
cause the Government to be named as an additional insured under any and 
all liability insurance policies. However, at the discretion of the 
Contracting Officer, such insurance need not be procured whenever the 
job order requires work on parts of a vessel only and the work is to be 
performed at a plant other than the site of the vessel. Further, the 
Contractor shall procure and maintain in force Workmen's Compensation 
Insurance (or its equivalent) covering its employees engaged in the work 
and shall insure the procurement and maintenance of such insurance by 
all subcontractors engaged in the work. The Contractor shall provide 
evidence of insurance as required by the Government.
    (e) The Contractor shall receive no allowance in the contract price 
for inclusion of any premium expense or charge for any reserve made on 
account of self-insurance for coverage against any risk assumed by the 
Government under this clause.
    (f) As soon as practicable after the occurrence of any loss or 
damage the risk of which the Government has assumed, written notice of 
the damage shall be given by the Contractor to the Contracting Officer. 
The notice shall contain full particulars of the loss or damage. If 
claim is made or suit is brought thereafter against the Contractor as 
the result or because of such event, the Contractor shall immediately 
deliver to the Government every demand, notice, summons or other process 
received by it or its representatives. The Contractor shall cooperate 
with the

[[Page 613]]

Government and, upon the Government's request, shall assist in effecting 
settlements, securing and giving evidence; obtaining the attendance of 
witnesses and in the conduct of suits. The Government shall pay to the 
Contractor the expense, other than the cost of maintaining the 
Contractor's usual organization, incurred in this assistance. Except at 
its own cost, the Contractor shall not voluntarily make any payment, 
assume any obligation or incur any expense not imperative for the 
protection of the vessel or vessels at the time of the event.

                             (End of clause)



1352.217-97  Title.

    As prescribed in 1317.7001(a), insert the following clause:

                   Title (CAR 1352.217-97) (Jan 1987)

    Unless title to materials and equipment acquired or produced for, or 
allocated to, the performance of this contract shall have vested 
previously in the Government by virtue of other provisions of this 
contract, title to all materials and equipment to be incorporated in any 
vessel or part thereof, or to be placed upon any vessel or part hereof 
in accordance with the requirements of the contract, shall vest in the 
Government upon delivery thereof at the plant or such other location as 
may be specified in the contract for the performance of the work. 
However, the Contractor is fully responsible for all such Contractor 
furnished materials and equipment or the restoration of any damaged 
work. It is expressly understood and agreed that the Contractor shall 
assume without limitation the risk of loss for any such materials and 
equipment until such time as all work is completed and accepted by the 
Government and the vessel is redelivered to the Government. Upon 
completion of the contract, or with the approval of the Contracting 
Officer at any time during the performance of the contract, all such 
Contractor furnished materials and equipment not incorporated in any 
vessel or part thereof, or not placed upon any vessel or part thereof, 
in accordance with the requirements of the contract, shall become the 
property of the Contractor, except those materials and equipment the 
cost of which has been reimbursed by the Government to the Contractor.

                             (End of clause)



1352.217-98  Discharge of liens.

    As prescribed in 1317.7001(a), insert the following clause:

             Discharge of Liens (CAR 1352.217-98) (Jan 1987)

    The Contractor shall immediately discharge or cause to be discharged 
any lien or right in rem of any kind, other than in favor of the 
Government, which at any time exists or arises in connection with work 
done or materials furnished under any contract hereunder with respect to 
the machinery, fittings, equipment or materials for any of the vessels. 
If any such lien or right in rem is not immediately discharged, the 
Government may discharge or cause to be discharged such lien or right at 
the expense of the Contractor.

                             (End of clause)



1352.217-99  Department of Labor occupational safety and health standards for ship repairing.

    As prescribed in 1317.7001(a), insert the following clause:

 Department of Labor Occupational Safety and Health Standards for Ship 
                 Repairing (CAR 1352.217-99) (Jan 1987)

    Attention of the Contractor is directed to the Occupational Safety 
and Health Act of 1970 (29 U.S.C. 651-678), and to the Occupational 
Safety and Health Standards for Shipyard Employment (29 CFR 1915), 
promulgated under Pub. L. 85-742, amending Section 41 of the 
Longshoremen's and Harbor Workers' Compensation Act (33 U.S.C. 941), and 
adopted by the Department of Labor as occupational safety or health 
standards under Section 6(a) of the Occupation Safety and Health Act of 
1970 (29 CFR 1910.13). These regulations apply to all ship repair and 
related work, as defined in the regulations, performed under this 
contract on the navigable waters of the United States, including any dry 
dock or marine railway. Nothing contained in this contract shall be 
construed as relieving the Contractor from any obligations which it may 
have for compliance with the aforesaid regulations.

                             (End of clause)



1352.217-100  Regulations governing asbestos work.

    As prescribed in 1317.7001(a), insert the following clause:

    Regulations Governing Asbestos Work (CAR 1352.217-100) (Jan 1987)

    If asbestos is encountered, the Contractor shall follow the 
regulations contained in 29 CFR 1910.1001 (OSHA, Chapter XVII).

[[Page 614]]

                             (End of clause)



1352.217-101  Complete and final equitable adjustments.

    As prescribed in 1317.7001(a), insert the following clause:

 Complete and Final Equitable Adjustments (CAR 1352.217-101) (Jan 1987)

    Whenever the Contractor submits any claim for an equitable 
adjustment attributable to any fact or circumstance regarded as a change 
order whether formal or ``constructive,'' under the Changes clause or 
any other clause of this contract, such claim shall include all 
adjustments (including but not limited to adjustments arising out of 
delays or disruptions or both caused by such change order) to which the 
Contractor is entitled under this contract. The foregoing requirement 
shall not preclude the Contractor from revising or resubmitting the 
claim prior to agreement upon the equitable adjustment for the change 
order. However, unless otherwise expressly agreed in the aforesaid 
supplemental agreement, the Contractor shall waive any right under the 
Changes clause or any other clause of this contract to further equitable 
adjustments attributable to such facts or circumstances giving rise to 
the claim upon the execution of the supplemental agreement setting forth 
the equitable adjustment. In any event, such right shall be deemed to be 
waived.

                             (End of clause)



1352.217-102  Government review, comment, acceptance, and approval.

    As prescribed in 1317.7001(a), insert the following clause:

 Government Review, Comment, Acceptance and Approval (CAR 1352.217-102) 
                               (Jan 1987)

    (a) Documentation, including drawings and other engineering products 
and reports, required by the contract to be submitted for review, 
comment, acceptance or approval will be acted upon by the Government 
within 30 calendar days after receipt by the Government, unless another 
period of time is specified.
    (b) Review, comment, acceptance or approval by the Government as 
required under this contract and applicable specifications shall not 
relieve the Contractor of its obligation to comply with the 
specifications and with all other requirements of the contract, nor 
shall it impose upon the Government any liability it would not have had 
in the absence of such review, comment and acceptance or approval.

                             (End of clause)



1352.217-103  Access to the vessel(s).

    As prescribed in 1317.7001(a), insert the following clause:

          Access to the Vessel(s) (CAR 1352.217-103) (Jan 1987)

    (a) As authorized by the Contracting Officer, a reasonable number of 
officers, employees and associates of the Government, or other prime 
Contractors with the Government and their subcontractors shall have 
admission to the plant and access to the vessel(s) at all reasonable 
times to perform and fulfill their respective obligations to the 
Government on a noninterference basis. The Contractor shall make 
reasonable arrangements to provide access for these personnel to office 
space, work areas, storage or shop areas, and other facilities and 
services, reasonable and necessary to performance of their respective 
duties. All such personnel shall comply with Contractor rules and 
regulations governing personnel at its shipyard, including those 
regarding safety and security.
    (b) The Contractor further agrees to allow a reasonable number of 
officers, employees, and associates of offerors on other contemplated 
work, the same privileges of admission to the Contractor's plant and 
access to the vessel(s) on a noninterference basis subject to Contractor 
rules and regulations governing personnel in its shipyard, including 
those regarding safety and security.

                             (End of clause)



1352.217-104  Documentation of requests for equitable adjustment.

    As prescribed in 1317.7001(a), insert the following clause:

 Documentation of Requests for Equitable Adjustment (CAR 1352.217-104) 
                               (Jan 1987)

    (a) For the purpose of this clause, the term ``change'' includes not 
only a change made pursuant to a written order designated as a ``change 
order'' but also any act or omission to act on the part of the 
Government where a request is made for equitable adjustment.
    (b) Whenever the Contractor requests or proposes an equitable 
adjustment to the contract price of not more than $100,000, for a change 
or an act or omission on the part of the Government, the request shall 
include a breakdown of the price adjustment in such form and supported 
by such reasonable detail as the Contracting Officer may request. As a 
minimum, the Contractor shall provide a breakdown of direct labor hours, 
labor dollars, overhead, material, subcontracts, contingencies and 
profit for each change and a

[[Page 615]]

justification for any extension of delivery date.
    (c) Whenever the Contractor requests or proposes an equitable 
adjustment of $100,000 gross (aggregate increases and/or decreases) or 
more to the price of the contract for a change made pursuant to a 
written order designated as a ``change order'' or whenever the 
Contractor requests an equitable adjustment in any amount for any other 
act or omission to act on the part of the Government, the proposal 
supporting such request shall contain the following information for each 
individual item or element of the request:
    (1) A description of (i) the unperformed work required by the 
contract before the change which has been deleted by the change and (ii) 
the work deleted by the change that already has been completed in whole 
or in part. The description shall include a list of components, 
equipment, and other identifiable property involved. Also, the status of 
manufacture, procurement, or installation of such property shall be 
indicated. A separate description shall be furnished for design and 
production work. Items of raw material, purchased parts, components, and 
other identifiable hardware which are made excess by the change, and 
which are not to be retained by the Contractor, are to be listed for 
later disposition;
    (2) A description of the work necessary to undo work already 
completed which has been deleted by the change;
    (3) A description of the work substituted or added by the change 
that was not required by the terms of the contract before the change. A 
list of components and equipment (not bulk material or items) involved, 
should be included. A separate description shall be furnished for design 
work and production work;
    (4) A description of any interference or inefficiency encountered in 
performing the change;
    (5) A description of disruption attributable solely to the change, 
which shall include the following information:
    (i) A specific description of each element of disruption which 
states how the work has been, or will be, disrupted;
    (ii) The calendar time period when disruption occurred, or will 
occur;
    (iii) The area(s) aboard ship where disruption occurred, or will 
occur;
    (iv) The trade(s) disrupted, with a breakdown of man-hours for each 
trade;
    (v) The scheduling of trades before, during, and after the period of 
disruption;
    (vi) A description of measures taken to lessen the disruptive effect 
of the change.
    (6) The delay in delivery attributable solely to the change;
    (7) A description of other work attributed to the change;
    (8) A narrative statement of the direct causal relationship between 
any alleged Government act or omission and the claimed result, cross-
referenced to the detailed information required above.
    (9) A statement setting forth a comparative enumeration of the 
amounts ``budgeted'' for the cost elements, including the materials 
cost, labor hours, and indirect costs pertinent to the change estimated 
by the Contractor in preparing his initial and ultimate proposal(s) for 
this contract, and the amounts claimed to have been incurred, or 
projected to be incurred, corresponding to each such ``budgeted cost'' 
element.
    (d) In addition to the information required by paragraph (b), each 
proposal submitted in support of a claim for equitable adjustment in the 
amount of $100,000 or more under any provision of this contract shall 
contain a duly executed Standard Form 1411 (Contract Pricing Proposal) 
for each individual claim item. The submitted Standard Form 1411 shall 
fully comply with Section 15.804-6 of the Federal Acquisition Regulation 
and any instructions on the reverse side of the form.
    (e) In addition to the information required by paragraph (c), each 
proposal submitted in support of a claim for equitable adjustment under 
any provision of this contract shall contain a duly executed SF-1411 
(Contracting Pricing Proposal) for each individual claim item. The 
submitted SF-1411 shall fully comply with Section 15.804-6 of the 
Federal Acquisition Regulation and any instructions on the reverse side 
of the form.
    (f) Individual claims for equitable adjustment may not encompass all 
of the factors listed in (c) above. Accordingly, the Contractor is 
required to set forth in his proposal information only with respect to 
those factors which are encompassed in the individual claim for 
equitable adjustment. In any event, the information furnished hereunder 
shall be in sufficient detail to permit the Contracting Officer to 
correlate the claimed increased costs or delay in delivery set forth in 
the SF-1411 (Contracting Pricing Proposal) with the information 
submitted pursuant to paragraph (c).

                             (End of clause)



1352.217-105  Change proposals.

    As prescribed in 1317.7001(a), insert the following clause:

             Change Proposals (CAR 1352.217-105) (Jan 1987)

    (a)(1) In addition to issuing changes under the Changes clause, the 
Contracting Officer may propose changes within the general scope of this 
contract, as set forth below. Within 10 days from the date of receipt of 
any such proposed change, or within such further time as the Contracting 
Officer may

[[Page 616]]

allow, the Contractor shall submit a scope of work, plans and sketches 
for the proposed change, and his estimate of: (i) the cost, (ii) the 
effect on the delivery date of the vessel, and (iii) the status of work 
on the ship affected by the proposed change. The proposed scope of work 
and estimate of the cost shall be in such form and supported by such 
reasonably detailed information as the Contracting Officer may require.
    (2) The Contractor's estimate shall be a firm offer for 30 days from 
receipt thereof by the cognizant Contracting Officer, unless extended by 
mutual consent. Within the time limit, the Contractor agrees to either 
(i) enter into a supplemental agreement covering the estimate as 
submitted or (ii) begin good faith negotiations at the request of the 
Contracting Officer, leading to the execution of a bilateral 
supplemental agreement, if the estimate as submitted is not satisfactory 
to the Contracting Officer. In either case, the supplemental agreement 
shall include an equitable adjustment for the preparatory work set forth 
above.
    (b) Pending execution of a bilateral agreement or the direction of 
the Contracting Officer pursuant to the Changes clause, the Contractor 
shall proceed diligently with contract performance without regard to the 
effect of any such proposed change.
    (c) Concurrently with the submission of any Change Proposal under 
this contract in which the proposed aggregate cost is $100,000 or 
greater, the Contractor shall submit to the Contracting Officer a 
completed Standard Form 1411. At the time of agreement upon the price of 
the Change Proposal, the Contractor shall submit a signed Certificate of 
Current Cost or Pricing Data.

                             (End of clause)



1352.217-106  Lay days.

    As prescribed in 1317.7001(a), insert the following clause:

                 Lay Days (CAR 1352.217-106) (Jan 1987)

    (a) Lay day time will be paid for by the Government at the 
Contractor's stipulated bid price for this item of the contract when the 
vessel remains on the dry dock or marine railways as a result of any 
Government change that involves work in addition to that required under 
the basic contract.
    (b) No amount for lay day time shall be paid until all accepted 
items of the basic contract for which a price was established by the 
Contractor and for which docking of the vessel was required have been 
satisfactorily completed.
    (c) Days of hauling out and floating, whatever the hour, shall not 
be paid as lay day time, and days when no work is performed by the 
Contractor shall not be paid as lay day time.
    (d) Payment of lay day time shall constitute complete compensation 
for all costs except for the direct cost of performing the changed work.

                             (End of clause)



1352.217-107  Changes--ship repair.

    As prescribed in 1317.7001(a), insert the following clause:

           Changes--Ship Repair (CAR 1352.217-107) (Jan 1987)

    (a) The Contracting Officer may at any time, by written order, and 
without notice to the sureties, if any, make changes within the general 
scope of this contract, in any one or more of the following:
    (1) Drawings, designs, or specifications, when the supplies to be 
furnished are to be specially manufactured for the Government in 
accordance with the drawings, designs, or specifications;
    (2) Method of shipment or packing;
    (3) Place of performance of the work;
    (4) Time of commencement or completion of the work; and
    (5) Other requirements within the general scope of the contract.
    (b) If any such change causes an increase or decrease in the cost 
of, or the time requried for, performance of any part of the work under 
this contract, whether changed or not changed by the order, the 
Contracting Officer shall make an equitable adjustment in the contract 
price, the delivery schedule, or both, and shall modify the contract.
    (c) The Contractor must submit any proposal for adjustment 
(hereafter referred to as proposal) under this clause within 10 days 
from the date of receipt of the written order. However, if the 
Contracting Officer decides that the facts justify it, the Contracting 
Officer may receive and act upon a proposal submitted before final 
payment of the contract.
    (d) If the Contractor's proposal includes the cost of property made 
obsolete or excess by the change, the Contracting Officer shall have the 
right to prescribe the manner of the disposition of the property.
    (e) Failure to agree to any adjustment shall be a dispute under the 
Disputes clause. However, nothing in this clause shall excuse the 
Contractor from proceeding with the contract as changed.

                             (End of clause)



1352.217-108  Default--ship repair.

    As prescribed in 1317.7001(a), insert the following clause:

[[Page 617]]

           Default--Ship Repair (CAR 1352.217-108) (Jan 1987)

    (a) The Government may, subject to paragraphs (c) and (d) of this 
clause, by written notice of default to the Contractor, terminate this 
contract in whole or in part if the Contractor fails to--
    (1) Deliver the supplies or to perform the services within the time 
specified in this contract or any extension;
    (2) Make progress, so as to endanger performance of this contract; 
or
    (3) Perform any of the other provisions of this contract.
    (b) If the Government terminates this contract in whole or in part, 
it may arrange for completion of the work in the manner the Contracting 
Officer considers appropriate. The Contracting Officer may designate any 
plant or plants for completion of the work, including the Contractor's 
plant or plants. If the work is to be completed at the Contractor's 
plant, the Government may use all tools, machinery, facilities and 
equipment of the Contractor which the Contracting Officer determines to 
be necessary. The Contractor will be liable to the Government for any 
excess costs, other than those costs attributable to changes in the 
plans or specifications made after the termination date. However, the 
Contractor shall continue the work not terminated.
    (c) Except for defaults of subcontractors at any tier, the 
Contractor shall not be liable for any excess costs if the failure to 
perform the contract arises from causes beyond the control and without 
the fault or negligence of the Contractor. Examples of such causes 
include (1) acts of God or of the public enemy, (2) acts of the 
Government in either its sovereign or contractual capacity, (3) fires, 
(4) floods, (5) epidemics, (6) quarantine restrictions, (7) strikes, (8) 
freight embargoes, and (9) unusually severe weather. In each instance 
the failure to perform must be beyond the control and without the fault 
or negligence of the Contractor.
    (d) If the failure to perform is caused by the default of a 
subcontractor at any tier, and if the cause of the default is beyond the 
control of both the Contractor and subcontractor, and without the fault 
or negligence of either, the Contractor shall not be liable for any 
excess costs for failure to perform, unless the subcontracted supplies 
or services were obtainable from other sources in sufficient time for 
the Contractor to meet the required delivery schedule.
    (e) If this contract is terminated for default, the Government may 
require the Contractor to transfer title and deliver to the Government, 
as directed by the Contracting Officer, any (1) completed supplies, and 
(2) partially completed supplies and materials, parts, tools, dies, 
jigs, fixtures, plans, drawings, information, and contract rights 
(collectively referred to as ``manufacturing materials'' in this clause) 
that the Contractor has specifically produced or acquired for the 
terminated portion of this contract. Upon direction of the Contracting 
Officer, the Contractor shall also protect and preserve property in its 
possession in which the Government has an interest.
    (f) The Government shall pay contract price for completed supplies 
delivered and accepted. The Contractor and Contracting Officer shall 
agree on the amount of payment for manufacturing materials delivered and 
accepted and for the protection and preservation of the property. 
Failure to agree will be a dispute under the Disputes clause. The 
Government may withhold from these amounts any sum the Contracting 
Officer determines to be necessary to protect the Government against 
loss because of outstanding liens or claims of former lien holders.
    (g) If, after termination, it is determined that the Contractor was 
not in default, or that the default was excusable, the rights and 
obligations of the parties shall be the same as if the termination had 
been issued for the convenience of the Government.
    (h) The rights and remedies of the Government in this clause are in 
addition to any other rights and remedies provided by law or under this 
contract.

                             (End of clause)



1352.217-109  Insurance requirements.

    As prescribed in 1317.7001(b), insert the following clause:

          Insurance Requirements (CAR 1352.217-109) (Jan 1987)

    (a) The Contractor shall procure and thereafter maintain the 
following insurance:
    (1) Ship repairer's legal liability insurance to insure the risks 
described in paragraph (b) of the Liability and Insurance clause. This 
insurance shall be for $300,000.
    (2) Comprehensive general liability insurance and automobile 
insurance to insure the risks described in paragraph (c) of the 
Liability and Insurance clause. This insurance shall be for $300,000 on 
account of any one accident or occurrence with respect to each vessel, 
boat, and/or barge upon which work is performed. The Contractor shall 
cause the Government to be named as an additional insured under any and 
all liability insurance policies.
    (3) Full coverage in accordance with the State Workmen's 
Compensation law; and
    (4) Full coverage in accordance with the United States 
Longshoremen's and Harbor Worker's Act.
    (b) As evidence that it has obtained the insurance specified in (a) 
above, the Contractor shall furnish the Contracting Officer with a 
certificate or certificates executed by

[[Page 618]]

an agent of the insurer authorized to execute such certificates. Such 
certificates shall be furnished prior to commencement of the work. Each 
certificate shall state that (name of insurer) has insured (name of 
Contractor) awarded contract number __________ for repair/alteration of 
(name of vessel) in accordance with the Liability and Insurance clause 
and the Insurance Requirements clause contained herein. Each certificate 
shall set forth that each policy of insurance represented thereby will 
expire on (date) and that each such policy contains the following 
clause:
    ``It is agreed that in the event of cancellation, or any material 
change in the policy adversely affecting the interest of the Government 
in this insurance 30 days prior written notice will be given to the 
Contracting Officer.''

                             (End of clause)



1352.217-110  Guarantees.

    As prescribed in 1317.7001(c), insert the following clause:

                Guarantees (CAR 1352.217-110) (Jan 1987)

    In case any work done or materials furnished by the Contractor under 
this contract on or for any vessel or the equipment thereof shall, 
within 90 days from the date of redelivery of the vessel by the 
Contractor, prove defective or deficient, such defects or deficiencies 
shall, as required by the Government in writing, be corrected and 
repaired by the Contractor or at Contractor expense to the satisfaction 
of the Contracting Officer. However, the Government shall be entitled to 
rely upon any guarantee secured by the Contractor or any subcontractor 
covering work done on materials furnished which exceeds the 90-day 
period until the expiration. Also, with respect to any individual work 
item identified and listed as incomplete at the redelivery of the 
vessel, the guarantee period shall run from the date of completion of 
such item. If and when practicable, the Government shall afford the 
Contractor an opportunity to effect such corrections and repairs itself. 
But, when it is impracticable or undesirable to return it to the 
Contractor, or the Contractor fails to proceed promptly with any such 
repairs as directed by the Contracting Officer, the corrections and 
repairs shall be made at Contractor expense at other Government 
designated locations. Where corrections and repairs are to be made by 
other than the Contractor, due to non-return of the vessel to the 
Contractor, the Contractor's liability may be discharged by an equitable 
deduction in the price of the contract. The Contractor's liability shall 
only extend for an additional 90-day guarantee period on those defects 
or deficiencies which it corrected and in no event to those for which 
payment was made. However, this clause does not limit the responsibility 
or relieve the liability of the Contractor under the Liability and 
Insurance clause. At the Contracting Officer's option, defects and 
deficiencies may be left in their uncorrected condition. In that event, 
the Contractor and the Contracting Officer shall agree on an equitable 
deduction from the contract price. If the Contractor and the Contracting 
Officer fail to agree upon an equitable deduction from the contract 
price, the dispute shall be determined in accordance with the Disputes 
clause.

                             (End of clause)



1352.217-111  Temporary services.

    As prescribed in 1317.7001(d), insert the following clause:

            Temporary Services (CAR 1352.217-111) (Jan 1987)

    (a) Temporary services are services incidental to the performance of 
work which are required in the schedule or specifications to be provided 
by the contractor. Temporary services may include the furnishing of 
water, electricity, telephone service, toilet facilities, garbage 
removal, office space, parking places, or similar facilities as 
specified in the schedule or specifications.
    (b) If performance time is extended due to Government caused delay 
or causes beyond the control of both the contractor and subcontractor, 
and without the fault or negligence of either, the contractor shall have 
the right to request an equitable adjustment for providing temporary 
services in excess of the number of estimated days contained in the 
schedule. Any such equitable adjustment shall not exceed the amount 
obtained by multiplying the number of excess days by the contractor's 
unit price contained in the schedule for this item.

                             (End of clause)



1352.217-112  Self-insurance information.

    As prescribed in 1317.7001(e), insert the following provision:

        Self-Insurance Information (CAR 1352.217-112) (Jan 1987)

    An offeror who proposes to self-insure for any or all of the risks 
set forth in the Liability and Insurance clause and the Insurance 
Requirements clause shall submit satisfactory evidence to permit the 
Contracting Officer to determine that the offeror's assets are 
sufficient for the risks set forth in such clauses. The offeror shall 
submit with its offer 2 certified copies of documents listing

[[Page 619]]

its assets and liabilities and other information deemed necessary by the 
offeror or required by the Contracting Officer. For approval of self-
insurance under the State Workmen's Compensation Law and the United 
States Longshoremen's and Harbor Workers' Act, evidence of 
qualifications as a self-insurer under the applicable compensation 
statute must be furnished to the Contracting Officer.

                           (End of provision)



1352.219-1  Women-owned small business sources.

    As prescribed in 1319.7003, insert the following provision:

              Women-Owned Small Busines Sources (May 1985)

    The contractor agrees to develop a list of qualified bidders that 
are women-owned small businesses. The Small Business Administration 
Procurement and Automated Source System (PASS) and the Minority Vendor 
Profile System (MVPS) may be used for this purpose. The contractor may 
contact the Department of Commerce, Office of Small and Disadvantaged 
Business Utilization (OSDBU) for assistance.
    The Contractor shall provide opportunities for women-owned small 
businesses to compete for subcontracts by making information on 
forthcoming opportunities available.
    Where the clause ``Small Business and Small Disadvantaged Business 
Subcontracting Plan'' is required in accordance with FAR 19.708(b), the 
contractor shall include qualified women-owned small businesses in the 
subcontracting plan.

                           (End of provision)

[51 FR 15333, Apr. 23, 1986]



1352.233-2  Service of protest.

    As prescribed in 1333.106, insert the following provision:

         Service of Protest (Jan 1985) (Deviation FAR 52.233-2)

    Protests, as defined in 33.101 of the Federal Acquisition 
Regulation, shall be served on the Contracting Officer and the Contract 
Law Division of the Office of the Assistant General Counsel for Finance 
and Litigation by obtaining written and dated acknowledgement of receipt 
from the Contracting Officer or the head of the contracting office or 
designee and from the Contract Law Division of the Office of the 
Assistant General Counsel for Finance and Litigation located at the U.S. 
Department of Commerce, Herbert C. Hoover Building, Room H5882, 14th St. 
between Pennsylvania and Constitution Avenues, NW., Washington, DC 
20230.

    [Insert the address of the contracting officer or refer to the 
number of the block on the Standard Form 33 or 1442, etc., where the 
address of the contracting offfice is located.]

                           (End of provision)

[51 FR 15333, Apr. 23, 1986]



PART 1353--FORMS--Table of Contents




Sec.
1353.000  Scope of part.

                         Subpart 1353.1--General

1353.103  Exceptions.

                  Subpart 1353.2--Prescription of Forms

1353.200  Scope of subpart.
1353.204  Administrative matters.
1353.204-2  Contract reporting (CD 409).
1353.213  Small purchase and other simplified purchase procedures (CD 
          404).
1353.232  Contract financing.
1353.232-2  (CD 45).


Appendix A--Forms [Note]

    Authority:  Federal Property and Administrative Services Act of 
1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of 
Commerce in Department Organization Order 10-5 and Department 
Administrative Order 208-2.

    Source:  49 FR 12965, Mar. 30, 1984, unless otherwise noted.



1353.000  Scope of part.

    This part supplements FAR Part 53 by prescribing specific exceptions 
to FAR prescribed forms for Department-wide use.



                         Subpart 1353.1--General



1353.103  Exceptions.

    The Department's policy is to use the FAR and CAR prescribed forms 
unless prior specific authority for exceptions or alterations has been 
obtained. Requests for exceptions to FAR or CAR forms shall be submitted 
to the Office of Procurement and Federal Assistance in the form 
prescribed by FAR 53.103 (See 1301.4 for authority to deviate).

[[Page 620]]



                  Subpart 1353.2--Prescription of Forms



1353.200  Scope of subpart.

    This subpart prescribes forms for Department-wide use which are 
exceptions to FAR prescribed forms. This subpart is arranged by subject 
matter, in the same order and keyed to the parts of the FAR or CAR in 
which the form use requirements are addressed.



1353.204  Administrative matters.



1353.204-2  Contract reporting (CD 409).

    (a) CD 409 (11/84) Report of Individual Procurement (over $10,000). 
CD 409 is prescribed for Department-wide use in reporting individual 
contract actions above $10,000, in lieu of SF 279.
[50 FR 19364, May 8, 1985, and 51 FR 1377, Jan. 13, 1986]



1353.213  Small purchase and other simplified purchase procedures (CD 404).

    (e) CD 404 (1/84) Supply, Equipment of Service Order. In lieu of OFs 
347 and 348, CD 404 is prescribed for Department-wide use as follows:
    (1) To accomplish small purchases
    (2) To issue orders under basic ordering agreements
    (3) To issue orders for paid advertisements
    (4) To issue orders for construction or dismantling, demolition, or 
removal of improvements.
[50 FR 19365, May 8, 1985, and 51 FR 1377, Jan. 13, 1986]



1353.232  Contract financing.

    A Department approved procurement request form certifies the 
availability of adequate funds for contract actions (See FAR 32.702). 
The Department's procurement request form also transmits technical and 
other specifications of the request, administrative approvals and 
clearances, and information for processing payments.
[50 FR 19365, May 8, 1985, and 51 FR 1377, Jan. 13, 1986]



1353.232-2  (CD 45).

    CD 45 (3/76) Requisitioning Form. CD 45 is prescribed for 
Department-wide use in requesting action from the servicing contract 
office. This form is the vehicle for administrative approvals, 
clearances, and certification of the availability of adequate funds as 
specified in FAR 32.702.

                            Appendix A--Forms

    Editorial Note: Appendix A published at 49 FR 12967, Mar. 30, 1984 
and confirmed at 51 FR 1377, Jan. 13, 1986, does not appear in the Code 
of Federal Regulations. For Federal Register citations affecting 
appendix A, see the List of CFR Sections Affected, in the Finding Aids 
section of this volume.

[[Page 621]]



                 CHAPTER 14--DEPARTMENT OF THE INTERIOR




  --------------------------------------------------------------------

                          SUBCHAPTER A--GENERAL
Part                                                                Page
1401            Department of the Interior Acquisition 
                    Regulation System.......................         622
1403            Improper business practices and personal 
                    conflicts of interest...................         622
             SUBCHAPTER B--ACQUISITION PLANNING  [RESERVED]
          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES
1415            Contracting by negotiation..................         624
                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS
1425            Foreign acquisition.........................         625
1426            Other socio-economic programs...............         625
             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS
1428            Bonds and insurance.........................         628
       SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING  [RESERVED]
              SUBCHAPTER G--CONTRACT MANAGEMENT  [RESERVED]
                     SUBCHAPTER H--CLAUSES AND FORMS
1452            Solicitation provisions and contract clauses         629
1453-1499

  [Reserved]

[[Page 622]]



                          SUBCHAPTER A--GENERAL





PART 1401--DEPARTMENT OF THE INTERIOR ACQUISITION REGULATION SYSTEM--Table of Contents




              Subpart 1401.1--Purpose, Authority, Issuance

Sec.
1401.106  OMB approval under the Paperwork Reduction Act.

             Subpart 1401.3--Agency Acquisition Regulations

1401.303  Publication and codification.

    Authority:  Sec. 205(c), 63 Stat. 390; 40 U.S.C. 486(c), and 5 
U.S.C. 301.

    Source:  49 FR 14252, Apr. 10, 1984, unless otherwise noted.



              Subpart 1401.1--Purpose, Authority, Issuance



1401.106  OMB approval under the Paperwork Reduction Act.

    The information collection and recordkeeping requirements have been 
approved by the Office of Management and Budget (OMB) as required by the 
Paperwork Reduction Act of 1995 (44 U.S.C. 3501 et seq.). The following 
OMB control numbers apply:

                                                                        
------------------------------------------------------------------------
                     DIAR segment                        OMB control No.
------------------------------------------------------------------------
1452.225-70...........................................         1084-0018
1452.226-70...........................................         1084-0019
------------------------------------------------------------------------

[62 FR 18054, Apr. 14, 1997]



             Subpart 1401.3--Agency Acquisition Regulations



1401.303  Publication and codification.

    (a)(1) Implementing and supplementing regulations issued under the 
DAIR System are codified under chapter 14 in title 48, Code of Federal 
Regulations and shall parallel the FAR in format, arrangement, and 
numbering system.
    (2)(i) Departmentwide regulations are assigned parts 1401 through 
1499 under 48 CFR, chapter 14.
    (ii) Where material in the FAR requires no implementation, there 
will be no corresponding number in the DIAR. Thus, there are gaps in the 
DIAR sequence of numbers where the FAR, as written, is deemed adequate. 
Supplementary material shall be numbered as specified in FAR 1.303.
    (3)(i) Bureauwide regulations are authorized for codification in 
appendices to chapter 14 as assigned by the Director, PAM.
    (ii) Regulations implementing the FAR or DIAR are numbered using 
parts 1401 through 1479. Supplementary material is numbered using parts 
1480 through 1499. Numbers for implementing or supplementing regulations 
by bureaus/offices are preceded by a prefix to the number 14 (indicating 
chapter 14--DIAR) for the organization indicated by lettered appendices 
as follows:
    (A) Bureau of Indian Affaris--BIA
    (B) Bureau of Reclamation--WBR
    (C) Interior Service Center--ISC
    (D) Bureau of Land Management--LLM
    (E) U.S. Geological Survey--WGS
    (F) Office of Surface Mining Reclamation and Enforcement--LSM
    (G) U.S. Minerals Management Service--LMS
    (H) National Park Service--FNP
    (I) U.S. Fish and Wildlife Service--FWS
    (e.g., FAR 1.3 then DIAR 1401.3 [Department level] then in appendix 
A, BIA 1401.3 [Bureau level])
    (b) [Reserved]
[62 FR 18054, Apr. 14, 1997]



PART 1403--IMPROPER BUSINESS PRACTICES AND PERSONAL CONFLICTS OF INTEREST--Table of Contents




            Subpart 1403.5--Other Improper Business Practices

Sec.
1403.570  Restrictions on contractor advertising.
1403.570-1  Policy.
1403.570-3  Contract clause.

    Authority:  Sec. 205(c), 63 Stat. 390; 40 U.S.C. 486(c), and 5 
U.S.C. 301.

    Source:  61 FR 5519, Feb. 13, 1996, unless otherwise noted.

[[Page 623]]



            Subpart 1403.5--Other Improper Business Practices



1403.570  Restrictions on contractor advertising.



1403.570-1  Policy.

    Award of a contract does not signify endorsement of the supplies or 
services purchased, nor does it signify agreement with any views 
espoused by officials of the awards. It is vital to the integrity of the 
procurement system to avoid even the appearance of an improper 
preference toward a particular vendor. Therefore, contractors shall not 
be permitted to publicize, or otherwise circulate, promotional materials 
which state or imply Governmental endorsement of a product, service or 
position which the contractor represents.



1403.570-3  Contract clause.

    CO's shall include the clause at 48 CFR 1452.203-70, Restriction on 
Endorsements, in all solicitations, contracts and agreements which are 
not executed in accordance with SAT procedures.

[[Page 624]]



            SUBCHAPTER B--ACQUISITION PLANNING    [RESERVED]





          SUBCHAPTER C--CONTRACTING METHODS AND CONTRACT TYPES





PART 1415--CONTRACTING BY NEGOTIATION--Table of Contents




          Subpart 1415.1--General Requirements for Negotiation

Sec.
1415.106  Contract clauses.
1415.106-70  Examination of records by the Department of the Interior 
          clause.

    Authority:  Sec. 205(c), 63 Stat. 390; 40 U.S.C. 486(c), and 5 
U.S.C. 301.

    Source:  49 FR 14259, Apr. 10, 1984, unless otherwise noted.



          Subpart 1415.1--General Requirements for Negotiation



1415.106  Contract clauses.



1415.106-70  Examination of records by the Department of the Interior clause.

    The contracting officer shall insert the clause at 1452.215-70, 
Examination of Records by the Department of the Interior, in all 
contracts requiring the clause a FAR 52.215-1, Examination of Records by 
the Comptroller General, as prescribed in FAR 15.106-1(b).

[[Page 625]]



                  SUBCHAPTER D--SOCIOECONOMIC PROGRAMS





PART 1425--FOREIGN ACQUISITION--Table of Contents




        Subpart 1425.2--Buy American Act--Construction Materials

Sec.
1425.203-70  Evaluating offers and price adjustment proposals.
1425.205  Solicitation provision and contract clause.

    Authority:  Sec. 205(c), 63 Stat. 390; 40 U.S.C. 486(c), and 5 
U.S.C. 301.

    Source:  61 FR 15390, Apr. 8, 1996, unless otherwise noted.



        Subpart 1425.2--Buy American Act--Construction Materials



1425.203-70  Evaluating offers and price adjustment proposals.

    (a) Upon receipt of an offered foreign construction material, the CO 
will conduct a 2 part test to determine, first, if the cost of the 
components made in the U.S. exceeds 50% of the cost for all the 
components; and second, if the item meets the first test, whether the 
item is manufactured in the U.S.
    (b) The cost of U.S. material is unreasonable if it exceeds the cost 
of the foreign construction material by more than 6%. The CO will 
compute the cost of construction material to include all delivery costs 
to the construction site, and any applicable duty (whether or not a 
duty-free entry certificate is issued.) This evaluation will be made for 
each foreign construction material proposed in the offer not excepted by 
the Government either in the solicitation at 48 CFR 1452.225-70(a) or by 
subsequent amendment.
    (c) The contractor shall pass to the Government any cost savings 
resulting from post-award approval to use foreign material. The CO may 
approve exceptions based on cost if the contractor can document that it 
used U.S. as well as foreign quotes to calculate the price it offered to 
the Government. If it is shown that the contractor did not obtain the 
quotes before award, the Director, PAM is authorized to disapprove 
requests for exceptions to the use of U.S. material. In case of 
disapproval, the contractor shall use the U.S. material and shall not 
pass on the additional cost of the U.S. material to the Government.



1425.205  Solicitation provision and contract clause.

    In addition to using the clauses required in FAR 25.205, the CO will 
insert the clause at 48 CFR 1452.225-70, Use of Foreign Construction 
Materials--Department of the Interior, in solicitations and contracts 
for construction, alteration, or repair inside the U.S. If the 
Government has determined that a U.S. construction material is 
unavailable, it will be listed under paragraph (a) of the clause.



PART 1426--OTHER SOCIO-ECONOMIC PROGRAMS--Table of Contents




                   Subpart 1426.70--Indian Preference

Sec.
1426.7000  Scope of subpart.
1426.7001  Definitions.
1426.7002  Statutory requirements.
1426.7003  Applicability and contract clause.
1426.7004  Compliance enforcement.
1426.7005  Tribal preference requirements.

    Authority:  Sec. 205(c), 63 Stat. 390 (40 U.S.C. 486(c) and 5 U.S.C. 
301); Pub. L. 93-638, 88 Stat. 2205 (25 U.S.C. 450e(b)).

    Source:  60 FR 53279, Oct. 13, 1995, unless otherwise noted.



                   Subpart 1426.70--Indian Preference



1426.7000  Scope of subpart.

    This subpart prescribes policies and procedures for implementation 
of section 7(b) of the Indian Self-Determination and Education 
Assistance Act (Public Law 93-638, 88 Stat. 2205, 25 U.S.C. 450e(b)).



1426.7001  Definitions.

    For purposes of this subpart the following definitions shall apply:
    Indian means a person who is a member of an Indian Tribe. If the 
contractor has reason to doubt that a person seeking employment 
preference is an Indian, the contractor shall grant the

[[Page 626]]

preference but shall require the individual within thirty (30) days to 
provide evidence from the Tribe concerned that the person is a member of 
the Tribe.
    Indian organization means that governing body of any Indian Tribe or 
entity established or recognized by such governing body in accordance 
with the Indian Financing Act of 1974 (Pub. L. 93-262, 88 Stat. 77; 25 
U.S.C. 1451).
    Indian-owned economic enterprise means any Indian-owned commercial, 
industrial, or business activity established or organized for the 
purpose of profit provided that such Indian ownership shall constitute 
not less than 51 percent of the enterprise.
    Indian reservation includes Indian reservations, public domain 
Indian allotments, former Indian reservations in Oklahoma, and land held 
by incorporated Native groups, regional corporations, and village 
corporations under the provisions of the Alaska Native Claims Settlement 
Act, (Pub. L. 92-203, 85 Stat. 688; 43 U.S.C. 1601 et seq.).
    Indian Tribe means an Indian Tribe, band, nation, or other 
recognized group or community, including any Alaska Native village or 
regional or village corporation as defined in or established pursuant to 
the Alaska Native Claims Settlement Act (Pub. L. 92-203, 85 Stat. 688; 
43 U.S.C. 1601), which is recognized as eligible for the special 
programs and services provided by the United States to Indians because 
of their status as Indians.
    On or near an Indian reservation means on a reservation or the 
distance within that area surrounding an Indian reservation(s) that a 
persons seeking employment could reasonably be expected to commute to 
and from in the course of a work day.



1426.7002  Statutory requirements.

    Section 7(b) of the Indian Self-Determination and Education 
Assistance Act requires that any contract or subcontract entered into 
pursuant to that Act, the Act of April 16, 1934 (48 Stat. 596; 25 U.S.C. 
452), as amended, (the Johnson-O'Malley Act), or any other Act 
authorizing contracts with Indian organizations or for the benefit of 
Indians shall require that, to the greatest extent feasible:
    (a) Preferences and opportunities for training and employment in 
connection with the administration of such contracts shall be given to 
Indians, and
    (b) Preference in the award of subcontracts in connection with the 
administration of such contracts shall be given to Indian organizations 
and to Indian-owned economic enterprises as defined in section 3 of the 
Indian Financing Act of 1974 (Sec. 3, Pub. L. 93-262; 88 Stat. 77; 25 
U.S.C. 1452).



1426.7003  Applicability and contract clause.

    (a) The Contracting Officer (CO) shall insert the clause at 
1452.226-70, Indian Preference--Department of the Interior, in 
solicitations issued and contracts awarded by
    (1) The Bureau of Indian Affairs,
    (2) A contracting activity other than the Bureau of Indian Affairs 
when the contract is entered into pursuant to an act specifically 
authorizing contracts with Indian organizations and
    (3) A contracting activity other than the Bureau of Indian Affairs 
where the work to be performed is specifically for the benefit of 
Indians and is in addition to any incidental benefits which might 
otherwise accrue to the general public.
    (b) The CO shall insert the clause at 1452.226-71, Indian Preference 
Program--Department of the Interior, in all solicitations issued and 
contracts awarded by a contracting activity which may exceed $50,000, 
which contain the clause required by paragraph (a) of this section and 
where it is determined by the CO, prior to solicitation, that the work 
under the contract will be performed in whole or in part on or near an 
Indian reservation(s). The Indian Preference Program clause may also be 
included in solicitations issued and contracts awarded by a contracting 
activity which may not exceed $50,000, but which contain the clause 
required by paragraph (a) of this section and which, in the opinion of 
the CO, offer substantial opportunities for Indian employment, training 
or subcontracting.

[[Page 627]]



1426.7004  Compliance enforcement.

    (a) The CO is responsible for conducting periodic reviews of the 
contractor to ensure compliance with the requirements of the clauses 
prescribed in 1426.7003. These reviews may be conducted with the 
assistance of the Indian Tribe(s) concerned.
    (b) Complaints of noncompliance with the requirements of the clauses 
prescribed under 1426.7003 which are received in writing by the 
contracting activity shall be promptly investigated by the CO and a 
written disposition of the complaint shall be prepared.



1426.7005  Tribal preference requirements.

    (a) Where the work under a contract is to be performed on an Indian 
reservation, the CO may supplement the clause at 1452.226-71, Indian 
Preference Program--Department of the Interior, by adding specific 
Indian preference requirements of the Tribe on whose reservation the 
work is to be performed. The supplemental requirements shall be jointly 
developed for the contract by the CO and the Tribe. Supplemental 
preference requirements must represent a further implementation of the 
requirements of section 7(b) of Public Law 93-638 and must be approved 
by the SOL for legal sufficiency before being added to a solicitation 
and resultant contract. Any supplemental preference requirements to be 
added to the clause at 1452.226-71 shall be included in the solicitation 
and clearly identified in order to ensure uniform understanding of the 
additional requirements by all prospective bidders or offerors.
    (b) Nothing in this subpart shall be interpreted to preclude Tribes 
from independently developing and enforcing their own tribal preference 
requirements. Such independently developed tribal preference 
requirements shall not, except as provided in paragraph (a) of this 
section, become a requirement in contracts covered under this subpart 
1426.70 and must not hinder the Government's right to award contracts 
and to administer their provisions.

[[Page 628]]



             SUBCHAPTER E--GENERAL CONTRACTING REQUIREMENTS





PART 1428--BONDS AND INSURANCE--Table of Contents




                        Subpart 1428.3--Insurance

Sec.
1428.301  Policy.
1428.306  Insurance under fixed-price contracts.
1428.306-70  Insurance for aircraft service contracts.
1428.311  Solicitation provision and contract clause on liability 
          insurance under cost-reimbursement contracts.
1428.311-2  Contract clause.

    Authority:  Sec. 205(c), 63 Stat. 390; 40 U.S.C. 486(c) and 5 U.S.C. 
301.

    Source:  60 FR 53280, Oct. 13, 1995, unless otherwise noted.



                        Subpart 1428.3--Insurance



1428.301  Policy.

    It is the policy of DOI to insure its own risks only when such 
action is in the best interest of the Government. Circumstances where 
contractors are required to carry insurance are listed under FAR 28.301 
and 28.306. In these circumstances, the CO shall insert the clause at 
1452.228-70, Liability Insurance--Department of the Interior, in 
solicitations and contracts.



1428.306  Insurance under fixed-price contracts.



1428.306-70  Insurance for aircraft services contracts.

    (a) Policy. The CO shall insert minimum insurance requirements in 
aircraft services contracts in order to protect the Government and its 
contractors.
    (b) Applicability. The clauses prescribed by paragraph (c) of this 
section are applicable to all fixed-price contracts involving use of 
aircraft with either a contractor-furnished or a Government-furnished 
pilot except for one-time charters when Government exposure is minimal 
and time limitations are present.
    (c) Clauses. The following clauses shall be used as prescribed:
    (1) The CO shall insert the clause at 1452.228-71, Aircraft and 
General Public Liability Insurance--Department of the Interior, in 
solicitations and contracts when a fixed-price contract for operation of 
aircraft where the Government is using a contractor-furnished pilot is 
contemplated.
    (2) The CO shall insert the clause at 1452.228-72, Liability for 
Loss or Damage--Department of the Interior, in solicitations and 
contracts when a fixed-price contract for use of aircraft where the 
Government does not have a property interest and is using a Government-
furnished pilot is contemplated.
    (3) The CO shall insert the clause at 1452.228-73, Liability for 
Loss or Damage--Department of the Interior (Property Interest), in 
solicitations and contracts when a fixed-price contract for use of 
aircraft where the Government has a property interest in the aircraft 
and is using a Government-furnished pilot (e.g., a lease with purchase 
option) is contemplated.



1428.311  Solicitation provision and contract clause on liability insurance under cost-reimbursement contracts.



1428.311-2  Contract clause.

    The CO shall modify the clause at FAR 52.228-7, Insurance--Liability 
to Third Persons, in accordance with 1452.228-7, and insert in 
solicitations and contracts as prescribed in FAR 28.311-2.

[[Page 629]]



      SUBCHAPTER F--SPECIAL CATEGORIES OF CONTRACTING    [RESERVED]





             SUBCHAPTER G--CONTRACT MANAGEMENT    [RESERVED]





                     SUBCHAPTER H--CLAUSES AND FORMS





PART 1452--SOLICITATION PROVISIONS AND CONTRACT CLAUSES--Table of Contents




Sec.
1452.000  Scope of part.

             Subpart 1452.2--Texts of Provisions and Clauses

1452.200  Scope of subpart.
1452.203-70  Restriction on endorsements.
1452.215-70  Examination of records by the Department of the Interior.
1452.215-71  Use and disclosure of proposal information.
1452.225-70  Use of foreign construction materials.
1452.226-70  Indian preference.
1452.226-71  Indian preference program.
1452.228-7  Insurance--liability to third persons.
1452.228-70  Liability insurance.
1452.228-71  Aircraft and general public liability.
1452.228-72  Liability for loss or damage.
1452.228-73  Liability for loss or damage (property interest).

    Authority:  Sec. 205(c), 63 Stat. 390; 40 U.S.C. 486(c), and 5 
U.S.C. 301.

    Source:  49 FR 14267, Apr. 10, 1984, unless otherwise noted.



1452.000  Scope of part.

    This part prescribes Department of the Interior provisions and 
clauses for use in acquisition.



             Subpart 1452.2--Texts of Provisions and Clauses



1452.200  Scope of subpart.

    This subpart sets forth the texts of all DIAR provisions and 
clauses. Consistent with the numbering scheme prescribed in FAR 52.101 
and the approach used in Far Subpart 52.2, this subpart is arranged by 
subject matter, in the same order as, and keyed to, the parts of the 
DIAR in which provisions and clause requirements are addressed.



1452.203-70  Restriction on endorsements.

    As prescribed in 48 CFR 1403.570-3, insert the following clause in 
all solicitations, contracts and agreements which are expected to exceed 
the simplified acquisition threshold.

   Restriction on Endorsements--Department of the Interior (Nov 1995)

    The contractor shall not refer to contracts awarded by the 
Department of the Interior in commercial advertising, as defined in FAR 
31.205-1, in a manner which states or implies that the product or 
service provided is approved or endorsed by the Government, or is 
considered by the Government to be superior to other products or 
services. This restriction is intended to avoid the appearance of 
preference by the Government toward any product or service. The 
contractor may request a determination as to the propriety of 
promotional material from the CO.

                             (End of clause)

[61 FR 5520, Feb. 13, 1995]



1452.215-70  Examination of records by the Department of the Interior.

    As prescribed in 1415.106-1, insert the following clause in all 
contracts containing the clause at FAR 52.215-1, Examination of Records 
by the Comptroller General (see FAR 15.106-1(b)):

   Examination of Records by the Department of the Interior (Apr 1984)

    For purposes of the Examination of Records by the Comptroller 
General (APR 1984) clause of this contract (FAR 52.214-1), the Secretary 
of the Interior, the Inspector General, and their duty authorized 
representative(s) from the Department of the Interior shall have the 
same access and examination rights as the Comptroller General of the 
United States.

[[Page 630]]

                             (End of clause)



1452.215-71  Use and disclosure of proposal information.

    As prescribed in 1415.413-70, insert the following provision in 
requests for proposals and requests for quotations instead of the 
provision at FAR 52.215-12:

 Use and Disclosure of Proposal Information--Department of the Interior 
                               (Apr 1984)

    (a) Definitions. For the purposes of this provision and the Freedom 
of Information Act (5 U.S.C. 552), the following terms shall have the 
meaning set forth below:
    (1) Trade Secret means an unpatented, secret, commercially valuable 
plan, appliance, formula, or process, which is used for making, 
preparing, compounding, treating or processing articles or materials, 
which are trade commodities.
    (2) Confidential commercial or financial information means any 
business information (other than trade secrets) which is exempt from the 
mandatory disclosure requirement of the Freedom of Information Act, 5 
U.S.C. 552. Exemptions from mandatory disclosure which may be applicable 
to business information contained in proposals include exemption (4), 
which covers ``commercial and financial information obtained from a 
person and privileged or confidential,'' and exemption (9), which covers 
``geological and geophysical information, including maps, concerning 
wells.''
    (b) If the offeror, or its subcontactor(s), believes that the 
proposal contains trade secrets or confidential commercial or financial 
information exempt from disclosure under the Freedom of Information Act, 
(5 U.S.C. 552), the cover page of each copy of the proposal shall be 
marked with the following legend:
    ``The information specifically identified on pages ____ of this 
proposal constitutes trade secrets or confidential commercial and 
financial information which the offeror believes to be exempt from 
disclosure under the Freedom of Information Act. The offeror requests 
that this information not be disclosed to the public, except as may be 
required by law. The offeror also requests that this information not be 
used in whole or part by the Government for any purpose other than to 
evaluate the proposal, except that if a contract is awarded to the 
offeror as a result of or in connection with the submission of the 
proposal, the Government shall have the right to use the information to 
the extent provided in the contract.''
    (c) The offeror shall also specifically identify trade secret 
information and confidential commerical and financial information on the 
pages of the proposal on which it appears and shall mark each such page 
with the following legend:
    ``This page contains trade secrets or confidential commercial and 
financial information which the offeror believes to be exempt from 
disclosure under the Freedom of Information Act and which is subject to 
the legend contained on the cover page of this proposal.''
    (d) Information in a proposal identified by an offeror as trade 
secret information or confidential commercial and financial information 
shall be used by the Government only for the purpose of evaluating the 
proposal, except that: (i) If a contract is awarded to the offeror as a 
result of or in connection with submission of the proposal, the 
Government shall have the right to use the information as provided in 
the contract, and (ii) if the same information is obtained from another 
source without restriction it may be used without restriction.
    (e) If a request under the Freedom of Information Act seeks access 
to information in a proposal identified as trade secret information or 
confidential commercial and financial information, full consideration 
will be given to the offeror's view that the information constitutes 
trade secrets or confidential commercial or financial information. The 
offeror will also be promptly notified of the request and given an 
opportunity to provide additional evidence and argument in support of 
its position, unless administratively unfeasible to do so. If it is 
determined that information claimed by the offeror to be trade secret 
information or confidential commercial or financial information is not 
exempt from disclosure under the Freedom of Information Act, the offeror 
will be notified of this determination prior to disclosure of the 
information.
    (f) The Government assumes no liability for the disclosure or use of 
information contained in a proposal if not marked in accordance with 
paragraphs (b) and (c) of this provision. If a request under the Freedom 
of Information Act is made for information in a proposal not marked in 
accordance with paragraphs (b) and (c) of this provision, the offeror 
concerned shall be promptly notified of the request and given an 
opportunity to provide its position to the Government. However, failure 
of an offeror to mark information contained in a proposal as trade 
secret information or confidential commercial or financial information 
will be treated by the Government as evidence that the information is 
not exempt from disclosure under the Freedom of Information Act, absent 
a showing that the failure to mark was due to unusual or extenuating 
circumstances, such as a showing that the offeror had intended to mark, 
but that markings were omitted from the offeror's proposal due to 
clerical error.

[[Page 631]]

                           (End of provision)



1425.225-70  Use of foreign construction materials.

    As prescribed in 48 CFR 1425.205, insert the following clause in 
solicitations and contracts for construction, alteration, or repair 
inside the United States:

 Use of Foreign Construction Materials--Department of the Interior (APR 
                                  1996)

    (a) The Government has determined that the Buy American Act is not 
applicable to the following construction materials because they are not 
mined, produced, or manufactured in the U.S. in sufficient quantities of 
a satisfactory quality:

 (1)____________________________________________________________________

 (2)____________________________________________________________________

 (3)____________________________________________________________________

    (b) Offers based on the use of foreign construction materials other 
than those listed in (a) above may be acceptable if the Government 
determines that U.S. construction material is not available, would be 
impracticable or constitute unreasonable price. Please contract the 
Contracting Officer with questions or comments concerning non-
availability or impracticability of U.S. material.
    (c)(1) Offers based upon use of foreign construction material for 
cost savings will be considered reasonable if the cost of each foreign 
construction material, plus 6 percent, is less than the cost of 
comparable U.S. construction material. The Contracting Officer will 
compute the cost of each foreign construction material to include all 
delivery costs to the construction site, and any applicable duty 
(whether or not a duty-free entry certificate is issued.) This 
evaluation will be made for each foreign construction material included 
in the offer but not listed in subparagraph (a) above in this clause.
    (2) Any contractor cost savings from post award approved 
substitution of foreign construction material for U.S. construction 
material shall be passed to the Government.
    (d)(1) This offer is based on the use of foreign construction 
material not listed in (a) above. For each foreign item proposed the 
offeror shall furnish the following information for the foreign material 
offered: item description, supplier, unit of measure, quantity, unit 
price, duty (even if a duty free certificate is issued), delivery costs, 
and total price. The offeror shall furnish the following information for 
each U.S. material comparable to the foreign material: item description, 
supplier, unit of measure, quantity, unit price, delivery costs and 
total price.
    (2) If the Government rejects the use of foreign construction 
material listed under paragraph (d)(1) above, the Government will 
evaluate the offer using the offeror's stated price for the comparable 
U.S. construction material, and the offeror shall be required to furnish 
such domestic construction material at the originally offered price. In 
preaward situations, an offer which does not state a price for a 
comparable U.S. construction material will be rejected by the 
Government. In postaward situations an offer proposing foreign material 
which does not state the price for the comparable U.S. construction 
material will be rejected by the Government. The contractor shall use 
comparable U.S. material for the project and any additional cost for the 
use of this U.S. material shall be absorbed by the contractor.

                             (End of clause)

[61 FR 15390, Apr. 8, 1996]



1452.226-70  Indian preference.

    As prescribed in 1404.7003(a), insert the following clause in 
solicitations issued and contracts awarded (a) by the Bureau of Indian 
Affairs except those pursuant to Title I and to Indian Tribes and Indian 
Organizations under Title II of Pub. L. 93-638 (25 U.S.C. 450 et seq. 
and 25 U.S.C. 455 et seq., respectively); (b) a contracting activity 
other than the Bureau of Indian Affairs when the contract is entered 
into pursuant to an act specifically authorizing contracts with Indian 
organizations, and (c) a contracting activity other than the Bureau of 
Indian Affairs when the work to be performed is specifically for the 
benefit of Indians and is in addition to any incidental benefits which 
might otherwise accrue to the general public.

        Indian Preference--Department of the Interior (Apr 1984)

    (a) The Contractor agrees to give preferences to Indians who can 
perform the work required regardless of age (subject to existing laws 
and regulations), sex, religion, or tribal affiliation for training and 
employment opportunities under this contract and, to the extent feasible 
consistent with the efficient performance of this contract, training and 
employment preferences and opportunities shall be provided to Indians 
regardless of age (subject to existing laws and regulations), sex, 
religion, or tribal affiliation who are not fully qualified to perform 
under this contract. The Contractor also agrees to give preference to 
Indian organizations and Indian-owned economic enterprises in the 
awarding of any subcontracts consistent with the efficient performance 
of this contract. The Contractor shall maintain such

[[Page 632]]

records as are necessary to indicate compliance with this paragraph.
    (b) In connection with the Indian employment preference requirements 
of this clause, the Contractor shall also provide opportunities for 
training incident to such employment. Such training shall include on-
the-job, classroom, or apprenticeship training which is designed to 
increase the vocational effectiveness of an Indian employee.
    (c) If the Contractor is unable to fill its training and employment 
needs after giving full consideration to Indians as required by this 
clause, those needs may be satisfied by selection of persons other than 
Indians in accordance with the clause of this contract entitled ``Equal 
Opportunity''.
    (d) If no Indian organizations or Indian-owned economic enterprises 
are available for awarding of subcontracts in connection with the work 
performed under this contract, the Contractor agrees to comply with the 
provisions of this contract involving utilization of small business 
concerns, small business concerns owned and controlled by socially and 
economically disadvantaged individuals, or labor surplus are concerns.
    (e) As used in this clause:
    (1) Indian means a person who is a member of an Indian Tribe. If the 
Contractor has reason to doubt that a person seeking employment 
preference is an Indian, the Contractor shall grant the preference but 
shall require the individual within thirty (30) days to provide evidence 
from the Tribe concerned that the person is a member of that Tribe.
    (2) Indian Tribe means an Indian Tribe, band, nation, or other 
organized group or community, including any Alaska Native village or 
regional or village corporation as defined in or established pursuant to 
the Alaska Native Claims Settlement Act (85 Stat. 668; 43 U.S.C. 1601) 
which is recognized as eligible for the special programs and services 
provided by the United States to Indians because of their status as 
Indians.
    (3) Indian organization means the governing body of any Indian Tribe 
or entity established or recognized by such governing body in accordance 
with the Indian Financing Act of 1974 (88 Stat. 77; 25 U.S.C. 1451); and
    (4) Indian-owned economic enterprise means any Indian-owned 
commercial, industrial, or business activity established or organized 
for the purpose of profit provided that such Indian ownership shall 
constitute not less than 51 percent of the enterprise.
    (f) The Contractor agrees to include the provisions of the clause 
including this paragraph (f) in each subcontract awarded under this 
contract.
    (g) In the event of noncompliance with this clause, the Contractor's 
right to proceed may be terminated in whole or in part by the 
Contracting Officer and the work completed in a manner determined by the 
Contracting Officer to be in the best interests of the Government.

                             (End of clause)

[49 FR 14267, Apr. 10, 1984. Redesignated at 60 FR 53280, Oct. 13, 1995]



1452.226-71  Indian preference program.

    As prescribed in 1404.7003(b), insert the following clause in all 
solicitations and contracts, awarded by the contacting activity which 
may exceed $50,000, and which contain the clause at 1452.204-71, and 
where it is determined by the Contracting Officer, prior to 
solicitation, that the work under the contract will be performed in 
whole or in part on or near an Indian reservation(s). The clause may 
also be included in solicitations issued and contracts awarded by a 
contracting activity which may not exceed $50,000 but which contain the 
clause at 1452.204-71 and which, in the opinion of the contracting 
officer, offer substantial opportunities for Indian employment, 
training, and subcontracting.

    Indian Preference Program--Department of the Interior (Apr 1984)

    (a) In addition to the requirements of the clause of this contract 
entitled ``Indian Preference--Department of the Interior'', the 
Contractor agrees to establish and conduct an Indian preference program 
which will expand the opportunities for Indian organizations and Indian-
owned economic enterprises to receive a preference in the awarding of 
subcontracts and which will expand opportunities for Indians to receive 
preference for training and employment in connection with the work to be 
performed under this contract. In this connection, the contractor shall:
    (1) Designate a liaison officer who will: (i) Maintain liaison with 
the Government and Tribe(s) on Indian preference matters; (ii) supervise 
compliance with the provisions of this clause; and (iii) administer the 
Contractor's Indian preference program.
    (2) Advise its recruitment sources in writing and include a 
statement in all advertisements for employment that Indian applicants 
will be given preference in employment and training incident to such 
employment.
    (3) Not less than twenty (20) calendar days prior to commencement of 
work under this contract, post a written notice in the Tribal office of 
any reservations on which or near where the work under this contract is 
to be performed, which sets forth the Contractor's

[[Page 633]]

employment needs and related training opportunities. The notice shall 
include the approximate number and types of employees needed, the 
approximate dates of employment; the experience or special skills 
required for employment, if any; training opportunities available; and 
all other pertinent information necessary to advise prospective 
employees of any other employment requirements. The Contractor shall 
also request the Tribe(s) on or near whose reservation(s) the work is to 
be performed to provide assistance to the Contractor in filling its 
employment needs and training opportunties. The Contracting Officer will 
advise the Contractor of the name, location, and phone number of the 
Tribal officials to contract in regard to the posting of notices and 
requests for Tribal assistance.
    (4) Establish and conduct a subcontracting program which gives 
preference to Indian organizations and Indian-owned economic enterprises 
as subcontractors and suppliers under this contract. Consistent with the 
efficient performance of this contract, the Contractor shall give public 
notice of existing subcontracting opportunities by soliciting bids or 
proposals only from Indian organizations or Indian-owned economic 
enterprises. The Contractor shall request assistance and information on 
Indian firms qualified as suppliers or subcontractors from the Tribe(s) 
on or near whose reservation(s) the work under the contract is to be 
performed. The Contracting Officer will advise the Contractor of the 
name, location, and phone number of the Tribal officials to be contacted 
in regard to the request for assistance and information. Public notices 
and solicitations for existing subcontracting opportunities shall 
provide an equitable opportunity for Indian firms to submit bids or 
proposals by including: (i) A clear description of the supplies or 
services required including quantities, specifications, and delivery 
schedules which facilitate the participation of Indian firms; (ii) a 
statement indicating the perference will be given to Indian 
organizations and Indian-owned economic enterprises in accordance with 
section 7(b) of Pub. L. 93-638; (88 Stat. 2205; 25 U.S.C. 450e(b)); 
(iii) definitions for the terms Indian organization and Indian-owned 
economic enterprise as prescribed under the ``Indian Preference--
Department of the Interior'' clause of this contract; (iv) a 
representation to be completed by the bidder or offeror that it is an 
Indian organization or Indian-owned economic enterprise; and (v) a 
closing date for receipt of bids or proposals which provides sufficient 
time for preparation and submission of a bid or proposal. If after 
soliciting bids from Indian organizations and Indian owned economic 
enterprises, no responsive bid is received, the Contractor shall comply 
with the requirements of paragraph (d) of the ``Indian Preference--
Department of the Interior'' clause of this contract. If one or more 
responsive bids are received, award shall be made to the low responsible 
bidder if the bid price is determined to be reasonable. If the low 
responsive bid is determined to be unreasonable as to price, the 
Contractor shall attempt to negotiate a reasonable price and award a 
subcontract. If a reasonable price cannot be agreed upon, the Contractor 
shall comply with the requirements of paragraph (d) of the ``Indian 
Preference--Department of the Interior'' clause of the contract.
    (5) Maintain written records under this contract which indicate: (i) 
The names and addresses of all Indians seeking employment for each 
employment position available under this contract; (ii) the number of 
types of positions filled by (A) Indians and (B) non-Indians, and the 
name, address and position of each Indian employed under this contract; 
(iii) for those positions where there are both Indian and non-Indian 
applicants, and a non-Indian is selected for employment, the reason(s) 
why the Indian applicant was not selected; (iv) actions taken to give 
preference to Indian organizations and Indian-owned economic enterprises 
for subcontracting opportunities which exist under this contract; (v) 
reasons why preference was not given to Indian firms as subcontractors 
or suppliers for each requirement where it was determined by the 
Contractor that such preference would not be consistent with the 
efficient performance of the contract, and (vi) the names and addresses 
of all Indian organizations and Indian-owned economic enterprises (A) 
contacted, and (B) receiving subcontract awards under this contract.
    (6) The Contractor shall submit to the Contracting Officer for 
approval a semiannual report which summarizes the Contractor's Indian 
preference program and indicates (i) the number and types of available 
positions filled and dollar amounts of all subcontracts awarded to (a) 
Indian organizations and Indian-owned economic enterprises and (b) all 
other firms.
    (7) Records maintained pursuant to this clause will be kept 
available for review by the Government until expiration of one (1) year 
after final payment under this contract, or for such longer period as 
may be required by any other clause of this contract or by applicable 
law or regulation.
    (b) For purposes of this clause, the following definitions of terms 
shall apply:
    (1) The terms Indian, Indian Tribe, Indian Organization, and Indian-
owned economic enterprise are defined in the clause of this contract 
entitled ``Indian Preference.''
    (2) Indian reservation includes Indian reservations, public domain 
Indian allotments, former Indian reservations in Oklahoma, and land held 
by incorporated Native groups, regional corporations, and village 
corporations under the provisions of the Alaska Native

[[Page 634]]

Claims Settlement Act (85 Stat. 688; 43 U.S.C. 1601 et seq.).
    (3) On or near an Indian Reservation means on a reservation or 
reservations or within that area surrounding an Indian reservation(s) 
where a person seeking employment could reasonably be expected to 
commute to and from in the course of a workday.
    (c) Nothing in the requirements of this clause shall be interpreted 
to preclude Indian Tribes from independently developing and enforcing 
their own Indian preference requirements. Such requirements must not 
hinder the Government's right to award contracts and to administer their 
provisions.
    (d) The Contractor agrees to include the provisions of this clause 
including this paragraph (d) in each subcontract awarded under this 
contract and to notify the Contracting Officer of such subcontracts.
    (e) In the event of noncompliance with this clause, the Contractor's 
right to proceed may be terminated in whole or in part by the 
Contracting Officer and the work completed in a manner determined by the 
Contracting Officer to be in the best interest of the Government.

                             (End of clause)

[49 FR 14267, Apr. 10, 1984. Redesignated at 60 FR 53280, Oct. 13, 1995]



1452.228-7  Insurance--liability to third persons.

    (a) As prescribed in 1428.311-2, the clause at FAR 52.228-7, 
Insurance-- Liability to Third Persons, shall be modified before 
insertion into solicitations and contracts by--
    (1) Changing the title of the clause to read ``Insurance--Liability 
to Third Persons (Apr. 1984) (Deviations)''; and
    (2) Changing the first sentence in subparagraph (c)(2) of the clause 
to read ``For certain liabilities (and expenses incidental to such 
liabilities) to third persons not compensated by insurance or otherwise 
but subject to the `Limitation of Cost' or `Limitation of Funds' clause 
of this contract.''
    (b) As prescribed in FAR 52.103(a) and 52.107(f), the clause at FAR 
52.252-6, Authorized Deviations in Clauses, shall be inserted into 
solicitations and contracts containing the clause in paragraph (a) of 
this section.



1452.228-70  Liability insurance.

    As prescribed in 1428.301, insert the following clause in all 
contracts where circumstances warrant the carrying of insurance by the 
contractor (see FAR 28.301 and 28.306):

       Liability Insurance--Department of the Interior (Jul 1995)

    (a) The contractor shall procure and maintain during the term of 
this contract and any extension thereof liability insurance in form 
satisfactory to the Contracting Officer by an insurance company which is 
acceptable to the Contracting Officer. The named insured parties under 
the policy shall be the Contractor and the United States of America. The 
amounts of the insurance shall be not less than as follows:

    $________ each person.*
    $________ each occurrence.*
    $________ property damage.*

    (b) Each policy shall have a certificate evidencing the insurance 
coverage. The insurance company shall provide an endorsement to notify 
the Contracting Officer 30 days prior to the effective date of 
cancellation or termination of the policy or certificate; or 
modification of the policy or certificate which may adversely affect the 
interest of the Government in such insurance. The certificate shall 
identify the contract number, the name and address of the Contracting 
Officer, as well as the insured, the policy number and a brief 
description of contract services to be performed. The contractor shall 
furnish the Contracting Officer with a copy of an acceptable insurance 
certificate prior to beginning the work.
    * These amounts to be set by the Contracting Officer.

                             (End of clause)

[60 FR 53280, Oct. 13, 1995]



1452.228-71  Aircraft and general public liability.

    As prescribed in 1428.306-70(c)(1), insert the following clause in 
all fixed-price contracts for operation of aircraft with contractor-
furnished pilot:

   Aircraft and General Public Liability Insurance--Department of the 
                            Interior     (  )

    (a) The contractor, at the contractor's expense, agrees to maintain, 
during the continuance of this contract, aircraft liability and general 
public liability insurance with limits of liability for (1) bodily 
injury to or death of aircraft passengers of not less than $75,000 for 
any one passenger and a limit for each occurance in any one aircraft of 
at least an amount equal to the sum produced by multiplying $75,000 by 
75 percent of the total number of passenger seats installed in the 
aircraft, (2) bodily injury or death of persons (excluding passengers) 
of not less than

[[Page 635]]

$75,000 for any one person in any one occurrence and $300,000 for each 
occurrence, and (3) property damage of not less than $100,000 for each 
occurrence, or (4) a single limit of liability for each occurrence equal 
to or greater than the combined required minimums set forth in (1) 
through (3) above.
    (b) The contractor agrees to maintain workers' compensation and 
other legally required insurance with respect to the contractor's own 
employees and agents.

                             (End of clause)

[54 FR 10989, Mar. 16, 1989]



1452.228-72  Liability for loss or damage.

    As prescribed in 1428.306-70(c)(2), insert the following clause in 
all fixed-price contracts involving the use of aircraft with Government-
furnished pilot where the Government does not have a property interest 
in the aircraft:

   Liability for Loss or Damage--Department of the Interior (Apr 1984)

    (a) The Contractor shall indemnify and hold the Government harmless 
from any and all loss or damage to the aircraft furnished under this 
contract except as provided in paragraph (d) of this clause. For the 
purpose of fulfilling its obligation under this clause, the Contractor 
shall procure and maintain during the term of this contract, and any 
extension thereof, hull insurance acceptable to the Contracting Officer. 
The Contractor's insurance coverage shall apply to pilots furnished by 
the Government who operate the aircraft. The contractor may request a 
list of Government pilots by name and qualification who are potential 
pilots.
    (b) Prior to the commencement of work hereunder, the Contractor 
shall furnish to the Contracting Officer a copy of the insurance policy 
or policies or a certificate of insurance issued by the underwriter(s) 
showing that the coverage required by this clause has been obtained.
    (c) Each policy or certificate evidencing the insurance shall 
contain an endorsement which provides that the insurance company will 
notify the Contracting Officer 30 days prior to the effective date of 
any cancellation or termination of any policy or certificate or any 
modification of a policy or certificate which adversely affects the 
interests of the Government in such insurance. The notice shall be sent 
by registered mail and shall identify this contract, the name and 
address of the contracting office, the policy, and the insured.
    (d) If the aircraft is damaged or destroyed while in the custody and 
control of the Government, the Government will reimburse the Contractor 
for the deductible stipulated in the insurance coverage (if any) as 
follows:
    (1) In-Motion Accidents--Up to 5% of the current insured value of 
the aircraft stated in the policy, or $10,000.00, whichever is less.
    (2) Not In-Motion Accidents--Up to $250.00 per accident. Such 
reimbursement shall not be made, however, for loss or damage to the 
aircraft resulting from: (1) Normal wear and tear, (2) negligence or 
fault in maintenance of the aircraft by the Contractor, or (3) a defect 
in construction of the aircraft or a component thereof.
    (e) If damage to the aircraft is established to be the fault of the 
Government, rental payments to the Contractor during the repair period 
will be made as set forth elsewhere in this contract. The Government 
may, at its option, make necessary repairs or return the aircraft to the 
Contractor for repair. In the event the aircraft is lost, destroyed, or 
damaged so extensively as to be beyond repair, no rental payment will be 
made to the Contractor thereafter.
    (f) Any failure to agree as to the responsibility of the Government 
or the Contractor under this clause shall, after a final finding and 
determination by the Contracting Officer, be considered a dispute within 
the meaning of the ``Disputes'' clause of this contract.

                             (End of clause)



1452.228-73  Liability for loss or damage (property interest).

    As prescribed in 1428.306-70(c)(3), insert the following clause in 
all fixed-price contracts involving the use of aircraft with Government-
furnished pilot where the Government has a property interest in the 
aircraft (e.g., lease with purchase option):

   Liability for Loss or Damage--Department of the Interior (Apr 1984)

    (a) The Government assumes all risk and liability for damage to or 
loss of the aircraft for the term of this contract, while the aircraft 
is in the Government's possession, except for: (1) Normal wear and tear 
to the aircraft, or (2) loss which occurs as a result of negligence or 
fault in maintenance of the aircraft by the contractor, or (3) loss 
resulting from a latent defect in the construction of the aircraft or a 
component thereof.
    (b) In the event of damage to the aircraft, the Government may, at 
its option, make the necessary repairs with its own facilities, or by 
contract, or pay the Contractor the reasonable cost of repair of the 
aircraft. If damage to the aircraft is established to be the fault of 
the Government, rental payments to the Contractor during the repair 
period will be made as set forth elsewhere in this contract.

[[Page 636]]

    (c) In the event the aircraft is lost, destroyed, or damaged so 
extensively as to be beyond repair, no rental payment will be made to 
the Contractor thereafter, but the Government will pay to the Contractor 
a sum equal to the fair market value of the aircraft just prior to such 
loss, destruction, or extensive damage less the salvage value of the 
aircraft.
    (d) The Contractor certifies that the contract price does not 
include any cost attributable to insurance or to any reserve fund it has 
established to protect its interests in or use of the aircraft, 
regardless of whether or not the insurance coverage applies for the 
period during which the Government has possession of the aircraft. If, 
in the event of loss or damage to the aircraft, the Contractor receives 
compensation for such loss or damage, in any form, from any source, the 
amount of such compensation shall be credited to the Government in 
determining the amount of the Government's liability under this clause; 
except that this shall not apply to proceeds of insurance received 
solely as an advance of insurance pending determination of Government 
liability, or for an increment of value of the aircraft beyond the value 
for which the Government is responsible.
    (e) In the event of loss or damage, the Government shall be 
subrogated to all rights of recovery by the Contractor against third 
parties for such loss or damage and such rights shall be immediately 
assigned to the Government. Except as the Contracting Officer may permit 
in writing, the Contractor shall neither release nor discharge any third 
party from liability for such loss or damage nor otherwise compromise or 
adversely affect the Government's subrogation or other rights hereunder. 
The Contractor shall cooperate with the Government in any suit or action 
undertaken by the Government against any such third party.
    (f) Any failure to agree as to the responsibility of the Government 
or the Contractor under this clause shall, after a final finding and 
determination by the Contracting Officer, be considered a dispute within 
the meaning of the ``Disputes'' clause of this contract.

                             (End of clause)

[49 FR 14267, Apr. 10, 1984, as amended at 60 FR 53280, Oct. 13, 1995]



PARTS 1453-1499 [RESERVED]



[[Page 637]]


                              FINDING AIDS




  --------------------------------------------------------------------

  A list of CFR titles, subtitles, chapters, subchapters and parts and 
an alphabetical list of agencies publishing in the CFR are included in 
the CFR Index and Finding Aids volume to the Code of Federal Regulations 
which is published separately and revised annually.
  Table of CFR Titles and Chapters
  Alphabetical List of Agencies Appearing in the CFR
  List of CFR Sections Affected



[[Page 639]]



                    Table of CFR Titles and Chapters




                   (Revised as of September 30, 1997)

                      Title 1--General Provisions

         I  Administrative Committee of the Federal Register 
                (Parts 1--49)
        II  Office of the Federal Register (Parts 50--299)
        IV  Miscellaneous Agencies (Parts 400--500)

                          Title 2--[Reserved]

                        Title 3--The President

         I  Executive Office of the President (Parts 100--199)

                           Title 4--Accounts

         I  General Accounting Office (Parts 1--99)
        II  Federal Claims Collection Standards (General 
                Accounting Office--Department of Justice) (Parts 
                100--299)

                   Title 5--Administrative Personnel

         I  Office of Personnel Management (Parts 1--1199)
        II  Merit Systems Protection Board (Parts 1200--1299)
       III  Office of Management and Budget (Parts 1300--1399)
        IV  Advisory Committee on Federal Pay (Parts 1400--1499)
         V  The International Organizations Employees Loyalty 
                Board (Parts 1500--1599)
        VI  Federal Retirement Thrift Investment Board (Parts 
                1600--1699)
       VII  Advisory Commission on Intergovernmental Relations 
                (Parts 1700--1799)
      VIII  Office of Special Counsel (Parts 1800--1899)
        IX  Appalachian Regional Commission (Parts 1900--1999)
        XI  Armed Forces Retirement Home (Part 2100)
       XIV  Federal Labor Relations Authority, General Counsel of 
                the Federal Labor Relations Authority and Federal 
                Service Impasses Panel (Parts 2400--2499)
        XV  Office of Administration, Executive Office of the 
                President (Parts 2500--2599)
       XVI  Office of Government Ethics (Parts 2600--2699)
       XXI  Department of the Treasury (Parts 3100--3199)
      XXII  Federal Deposit Insurance Corporation (Part 3201)
     XXIII  Department of Energy (Part 3301)

[[Page 640]]

      XXIV  Federal Energy Regulatory Commission (Part 3401)
      XXVI  Department of Defense (Part 3601)
    XXVIII  Department of Justice (Part 3801)
      XXIX  Federal Communications Commission (Parts 3900--3999)
       XXX  Farm Credit System Insurance Corporation (Parts 4000--
                4099)
      XXXI  Farm Credit Administration (Parts 4100--4199)
    XXXIII  Overseas Private Investment Corporation (Part 4301)
      XXXV  Office of Personnel Management (Part 4501)
        XL  Interstate Commerce Commission (Part 5001)
       XLI  Commodity Futures Trading Commission (Part 5101)
      XLII  Department of Labor (Part 5201)
     XLIII  National Science Foundation (Part 5301)
       XLV  Department of Health and Human Services (Part 5501)
      XLVI  Postal Rate Commission (Part 5601)
     XLVII  Federal Trade Commission (Part 5701)
    XLVIII  Nuclear Regulatory Commission (Part 5801)
         L  Department of Transportation (Part 6001)
       LII  Export-Import Bank of the United States (Part 6201)
      LIII  Department of Education (Parts 6300--6399)
       LIV  Environmental Protection Agency (Part 6401)
      LVII  General Services Administration (Part 6701)
     LVIII  Board of Governors of the Federal Reserve System (Part 
                6801)
       LIX  National Aeronautics and Space Administration (Part 
                6901)
        LX  United States Postal Service (Part 7001)
       LXI  National Labor Relations Board (Part 7101)
      LXII  Equal Employment Opportunity Commission (Part 7201)
     LXIII  Inter-American Foundation (Part 7301)
       LXV  Department of Housing and Urban Development (Part 
                7501)
      LXVI  National Archives and Records Administration (Part 
                7601)
      LXIX  Tennessee Valley Authority (Part 7901)
      LXXI  Consumer Product Safety Commission (Part 8101)
     LXXIV  Federal Mine Safety and Health Review Commission (Part 
                8401)
     LXXVI  Federal Retirement Thrift Investment Board (Part 8601)
    LXXVII  Office of Management and Budget (Part 8701)

                          Title 6--[Reserved]

                         Title 7--Agriculture

            Subtitle A--Office of the Secretary of Agriculture 
                (Parts 0--26)
            Subtitle B--Regulations of the Department of 
                Agriculture
         I  Agricultural Marketing Service (Standards, 
                Inspections, Marketing Practices), Department of 
                Agriculture (Parts 27--209)
        II  Food and Consumer Service, Department of Agriculture 
                (Parts 210--299)

[[Page 641]]

       III  Animal and Plant Health Inspection Service, Department 
                of Agriculture (Parts 300--399)
        IV  Federal Crop Insurance Corporation, Department of 
                Agriculture (Parts 400--499)
         V  Agricultural Research Service, Department of 
                Agriculture (Parts 500--599)
        VI  Natural Resources Conservation Service, Department of 
                Agriculture (Parts 600--699)
       VII  Farm Service Agency, Department of Agriculture (Parts 
                700--799)
      VIII  Grain Inspection, Packers and Stockyards 
                Administration (Federal Grain Inspection Service), 
                Department of Agriculture (Parts 800--899)
        IX  Agricultural Marketing Service (Marketing Agreements 
                and Orders; Fruits, Vegetables, Nuts), Department 
                of Agriculture (Parts 900--999)
         X  Agricultural Marketing Service (Marketing Agreements 
                and Orders; Milk), Department of Agriculture 
                (Parts 1000--1199)
        XI  Agricultural Marketing Service (Marketing Agreements 
                and Orders; Miscellaneous Commodities), Department 
                of Agriculture (Parts 1200--1299)
      XIII  Northeast Dairy Compact Commission (Parts 1300--1399)
       XIV  Commodity Credit Corporation, Department of 
                Agriculture (Parts 1400--1499)
        XV  Foreign Agricultural Service, Department of 
                Agriculture (Parts 1500--1599)
       XVI  Rural Telephone Bank, Department of Agriculture (Parts 
                1600--1699)
      XVII  Rural Utilities Service, Department of Agriculture 
                (Parts 1700--1799)
     XVIII  Rural Housing Service, Rural Business-Cooperative 
                Service, Rural Utilities Service, and Farm Service 
                Agency, Department of Agriculture (Parts 1800--
                2099)
      XXVI  Office of Inspector General, Department of Agriculture 
                (Parts 2600--2699)
     XXVII  Office of Information Resources Management, Department 
                of Agriculture (Parts 2700--2799)
    XXVIII  Office of Operations, Department of Agriculture (Parts 
                2800--2899)
      XXIX  Office of Energy, Department of Agriculture (Parts 
                2900--2999)
       XXX  Office of the Chief Financial Officer, Department of 
                Agriculture (Parts 3000--3099)
      XXXI  Office of Environmental Quality, Department of 
                Agriculture (Parts 3100--3199)
     XXXII  [Reserved]
    XXXIII  Office of Transportation, Department of Agriculture 
                (Parts 3300--3399)
     XXXIV  Cooperative State Research, Education, and Extension 
                Service, Department of Agriculture (Parts 3400--
                3499)
      XXXV  Rural Housing Service, Department of Agriculture 
                (Parts 3500--3599)

[[Page 642]]

     XXXVI  National Agricultural Statistics Service, Department 
                of Agriculture (Parts 3600--3699)
    XXXVII  Economic Research Service, Department of Agriculture 
                (Parts 3700--3799)
   XXXVIII  World Agricultural Outlook Board, Department of 
                Agriculture (Parts 3800--3899)
       XLI  [Reserved]
      XLII  Rural Business-Cooperative Service and Rural Utilities 
                Service, Department of Agriculture (Parts 4200--
                4299)

                    Title 8--Aliens and Nationality

         I  Immigration and Naturalization Service, Department of 
                Justice (Parts 1--499)

                 Title 9--Animals and Animal Products

         I  Animal and Plant Health Inspection Service, Department 
                of Agriculture (Parts 1--199)
        II  Grain Inspection, Packers and Stockyards 
                Administration (Packers and Stockyards Programs), 
                Department of Agriculture (Parts 200--299)
       III  Food Safety and Inspection Service, Meat and Poultry 
                Inspection, Department of Agriculture (Parts 300--
                599)

                           Title 10--Energy

         I  Nuclear Regulatory Commission (Parts 0--199)
        II  Department of Energy (Parts 200--699)
       III  Department of Energy (Parts 700--999)
         X  Department of Energy (General Provisions) (Parts 
                1000--1099)
        XI  United States Enrichment Corporation (Parts 1100--
                1199)
        XV  Office of the Federal Inspector for the Alaska Natural 
                Gas Transportation System (Parts 1500--1599)
      XVII  Defense Nuclear Facilities Safety Board (Parts 1700--
                1799)

                      Title 11--Federal Elections

         I  Federal Election Commission (Parts 1--9099)

                      Title 12--Banks and Banking

         I  Comptroller of the Currency, Department of the 
                Treasury (Parts 1--199)
        II  Federal Reserve System (Parts 200--299)
       III  Federal Deposit Insurance Corporation (Parts 300--399)
        IV  Export-Import Bank of the United States (Parts 400--
                499)
         V  Office of Thrift Supervision, Department of the 
                Treasury (Parts 500--599)
        VI  Farm Credit Administration (Parts 600--699)
       VII  National Credit Union Administration (Parts 700--799)

[[Page 643]]

      VIII  Federal Financing Bank (Parts 800--899)
        IX  Federal Housing Finance Board (Parts 900--999)
        XI  Federal Financial Institutions Examination Council 
                (Parts 1100--1199)
       XIV  Farm Credit System Insurance Corporation (Parts 1400--
                1499)
        XV  Thrift Depositor Protection Oversight Board (Parts 
                1500--1599)
      XVII  Office of Federal Housing Enterprise Oversight, 
                Department of Housing and Urban Development (Parts 
                1700-1799)
     XVIII  Community Development Financial Institutions Fund, 
                Department of the Treasury (Parts 1800--1899)

               Title 13--Business Credit and Assistance

         I  Small Business Administration (Parts 1--199)
       III  Economic Development Administration, Department of 
                Commerce (Parts 300--399)

                    Title 14--Aeronautics and Space

         I  Federal Aviation Administration, Department of 
                Transportation (Parts 1--199)
        II  Office of the Secretary, Department of Transportation 
                (Aviation Proceedings) (Parts 200--399)
       III  Commercial Space Transportation, Federal Aviation 
                Administration, Department of Transportation 
                (Parts 400--499)
         V  National Aeronautics and Space Administration (Parts 
                1200--1299)

                 Title 15--Commerce and Foreign Trade

            Subtitle A--Office of the Secretary of Commerce (Parts 
                0--29)
            Subtitle B--Regulations Relating to Commerce and 
                Foreign Trade
         I  Bureau of the Census, Department of Commerce (Parts 
                30--199)
        II  National Institute of Standards and Technology, 
                Department of Commerce (Parts 200--299)
       III  International Trade Administration, Department of 
                Commerce (Parts 300--399)
        IV  Foreign-Trade Zones Board, Department of Commerce 
                (Parts 400--499)
       VII  Bureau of Export Administration, Department of 
                Commerce (Parts 700--799)
      VIII  Bureau of Economic Analysis, Department of Commerce 
                (Parts 800--899)
        IX  National Oceanic and Atmospheric Administration, 
                Department of Commerce (Parts 900--999)
        XI  Technology Administration, Department of Commerce 
                (Parts 1100--1199)
      XIII  East-West Foreign Trade Board (Parts 1300--1399)
       XIV  Minority Business Development Agency (Parts 1400--
                1499)

[[Page 644]]

            Subtitle C--Regulations Relating to Foreign Trade 
                Agreements
        XX  Office of the United States Trade Representative 
                (Parts 2000--2099)
            Subtitle D--Regulations Relating to Telecommunications 
                and Information
     XXIII  National Telecommunications and Information 
                Administration, Department of Commerce (Parts 
                2300--2399)

                    Title 16--Commercial Practices

         I  Federal Trade Commission (Parts 0--999)
        II  Consumer Product Safety Commission (Parts 1000--1799)

             Title 17--Commodity and Securities Exchanges

         I  Commodity Futures Trading Commission (Parts 1--199)
        II  Securities and Exchange Commission (Parts 200--399)
        IV  Department of the Treasury (Parts 400--499)

          Title 18--Conservation of Power and Water Resources

         I  Federal Energy Regulatory Commission, Department of 
                Energy (Parts 1--399)
       III  Delaware River Basin Commission (Parts 400--499)
        VI  Water Resources Council (Parts 700--799)
      VIII  Susquehanna River Basin Commission (Parts 800--899)
      XIII  Tennessee Valley Authority (Parts 1300--1399)

                       Title 19--Customs Duties

         I  United States Customs Service, Department of the 
                Treasury (Parts 1--199)
        II  United States International Trade Commission (Parts 
                200--299)
       III  International Trade Administration, Department of 
                Commerce (Parts 300--399)

                     Title 20--Employees' Benefits

         I  Office of Workers' Compensation Programs, Department 
                of Labor (Parts 1--199)
        II  Railroad Retirement Board (Parts 200--399)
       III  Social Security Administration (Parts 400--499)
        IV  Employees' Compensation Appeals Board, Department of 
                Labor (Parts 500--599)
         V  Employment and Training Administration, Department of 
                Labor (Parts 600--699)
        VI  Employment Standards Administration, Department of 
                Labor (Parts 700--799)
       VII  Benefits Review Board, Department of Labor (Parts 
                800--899)
      VIII  Joint Board for the Enrollment of Actuaries (Parts 
                900--999)

[[Page 645]]

        IX  Office of the Assistant Secretary for Veterans' 
                Employment and Training, Department of Labor 
                (Parts 1000--1099)

                       Title 21--Food and Drugs

         I  Food and Drug Administration, Department of Health and 
                Human Services (Parts 1--1299)
        II  Drug Enforcement Administration, Department of Justice 
                (Parts 1300--1399)
       III  Office of National Drug Control Policy (Parts 1400--
                1499)

                      Title 22--Foreign Relations

         I  Department of State (Parts 1--199)
        II  Agency for International Development, International 
                Development Cooperation Agency (Parts 200--299)
       III  Peace Corps (Parts 300--399)
        IV  International Joint Commission, United States and 
                Canada (Parts 400--499)
         V  United States Information Agency (Parts 500--599)
        VI  United States Arms Control and Disarmament Agency 
                (Parts 600--699)
       VII  Overseas Private Investment Corporation, International 
                Development Cooperation Agency (Parts 700--799)
        IX  Foreign Service Grievance Board Regulations (Parts 
                900--999)
         X  Inter-American Foundation (Parts 1000--1099)
        XI  International Boundary and Water Commission, United 
                States and Mexico, United States Section (Parts 
                1100--1199)
       XII  United States International Development Cooperation 
                Agency (Parts 1200--1299)
      XIII  Board for International Broadcasting (Parts 1300--
                1399)
       XIV  Foreign Service Labor Relations Board; Federal Labor 
                Relations Authority; General Counsel of the 
                Federal Labor Relations Authority; and the Foreign 
                Service Impasse Disputes Panel (Parts 1400--1499)
        XV  African Development Foundation (Parts 1500--1599)
       XVI  Japan-United States Friendship Commission (Parts 
                1600--1699)
      XVII  United States Institute of Peace (Parts 1700--1799)

                          Title 23--Highways

         I  Federal Highway Administration, Department of 
                Transportation (Parts 1--999)
        II  National Highway Traffic Safety Administration and 
                Federal Highway Administration, Department of 
                Transportation (Parts 1200--1299)
       III  National Highway Traffic Safety Administration, 
                Department of Transportation (Parts 1300--1399)

[[Page 646]]

                Title 24--Housing and Urban Development

            Subtitle A--Office of the Secretary, Department of 
                Housing and Urban Development (Parts 0--99)
            Subtitle B--Regulations Relating to Housing and Urban 
                Development
         I  Office of Assistant Secretary for Equal Opportunity, 
                Department of Housing and Urban Development (Parts 
                100--199)
        II  Office of Assistant Secretary for Housing-Federal 
                Housing Commissioner, Department of Housing and 
                Urban Development (Parts 200--299)
       III  Government National Mortgage Association, Department 
                of Housing and Urban Development (Parts 300--399)
         V  Office of Assistant Secretary for Community Planning 
                and Development, Department of Housing and Urban 
                Development (Parts 500--599)
        VI  Office of Assistant Secretary for Community Planning 
                and Development, Department of Housing and Urban 
                Development (Parts 600--699) [Reserved]
       VII  Office of the Secretary, Department of Housing and 
                Urban Development (Housing Assistance Programs and 
                Public and Indian Housing Programs) (Parts 700--
                799)
      VIII  Office of the Assistant Secretary for Housing--Federal 
                Housing Commissioner, Department of Housing and 
                Urban Development (Section 8 Housing Assistance 
                Programs and Section 202 Direct Loan Program) 
                (Parts 800--899)
        IX  Office of Assistant Secretary for Public and Indian 
                Housing, Department of Housing and Urban 
                Development (Parts 900--999)
         X  Office of Assistant Secretary for Housing--Federal 
                Housing Commissioner, Department of Housing and 
                Urban Development (Interstate Land Sales 
                Registration Program) (Parts 1700--1799)
       XII  Office of Inspector General, Department of Housing and 
                Urban Development (Parts 2000--2099)
        XX  Office of Assistant Secretary for Housing--Federal 
                Housing Commissioner, Department of Housing and 
                Urban Development (Parts 3200--3899)
       XXV  Neighborhood Reinvestment Corporation (Parts 4100--
                4199)

                           Title 25--Indians

         I  Bureau of Indian Affairs, Department of the Interior 
                (Parts 1--299)
        II  Indian Arts and Crafts Board, Department of the 
                Interior (Parts 300--399)
       III  National Indian Gaming Commission, Department of the 
                Interior (Parts 500--599)
        IV  Office of Navajo and Hopi Indian Relocation (Parts 
                700--799)
         V  Bureau of Indian Affairs, Department of the Interior, 
                and Indian Health Service, Department of Health 
                and Human Services (Part 900)
        VI  Office of the Assistant Secretary-Indian Affairs, 
                Department of the Interior (Part 1001)

[[Page 647]]

       VII  Office of the Special Trustee for American Indians, 
                Department of the Interior (Part 1200)

                      Title 26--Internal Revenue

         I  Internal Revenue Service, Department of the Treasury 
                (Parts 1--799)

           Title 27--Alcohol, Tobacco Products and Firearms

         I  Bureau of Alcohol, Tobacco and Firearms, Department of 
                the Treasury (Parts 1--299)

                   Title 28--Judicial Administration

         I  Department of Justice (Parts 0--199)
       III  Federal Prison Industries, Inc., Department of Justice 
                (Parts 300--399)
         V  Bureau of Prisons, Department of Justice (Parts 500--
                599)
        VI  Offices of Independent Counsel, Department of Justice 
                (Parts 600--699)
       VII  Office of Independent Counsel (Parts 700--799)

                            Title 29--Labor

            Subtitle A--Office of the Secretary of Labor (Parts 
                0--99)
            Subtitle B--Regulations Relating to Labor
         I  National Labor Relations Board (Parts 100--199)
        II  Office of Labor-Management Standards, Department of 
                Labor (Parts 200--299)
       III  National Railroad Adjustment Board (Parts 300--399)
        IV  Office of Labor-Management Standards, Department of 
                Labor (Parts 400--499)
         V  Wage and Hour Division, Department of Labor (Parts 
                500--899)
        IX  Construction Industry Collective Bargaining Commission 
                (Parts 900--999)
         X  National Mediation Board (Parts 1200--1299)
       XII  Federal Mediation and Conciliation Service (Parts 
                1400--1499)
       XIV  Equal Employment Opportunity Commission (Parts 1600--
                1699)
      XVII  Occupational Safety and Health Administration, 
                Department of Labor (Parts 1900--1999)
        XX  Occupational Safety and Health Review Commission 
                (Parts 2200--2499)
       XXV  Pension and Welfare Benefits Administration, 
                Department of Labor (Parts 2500--2599)
     XXVII  Federal Mine Safety and Health Review Commission 
                (Parts 2700--2799)
        XL  Pension Benefit Guaranty Corporation (Parts 4000--
                4999)

[[Page 648]]

                      Title 30--Mineral Resources

         I  Mine Safety and Health Administration, Department of 
                Labor (Parts 1--199)
        II  Minerals Management Service, Department of the 
                Interior (Parts 200--299)
       III  Board of Surface Mining and Reclamation Appeals, 
                Department of the Interior (Parts 300--399)
        IV  Geological Survey, Department of the Interior (Parts 
                400--499)
        VI  Bureau of Mines, Department of the Interior (Parts 
                600--699)
       VII  Office of Surface Mining Reclamation and Enforcement, 
                Department of the Interior (Parts 700--999)

                 Title 31--Money and Finance: Treasury

            Subtitle A--Office of the Secretary of the Treasury 
                (Parts 0--50)
            Subtitle B--Regulations Relating to Money and Finance
         I  Monetary Offices, Department of the Treasury (Parts 
                51--199)
        II  Fiscal Service, Department of the Treasury (Parts 
                200--399)
        IV  Secret Service, Department of the Treasury (Parts 
                400--499)
         V  Office of Foreign Assets Control, Department of the 
                Treasury (Parts 500--599)
        VI  Bureau of Engraving and Printing, Department of the 
                Treasury (Parts 600--699)
       VII  Federal Law Enforcement Training Center, Department of 
                the Treasury (Parts 700--799)
      VIII  Office of International Investment, Department of the 
                Treasury (Parts 800--899)

                      Title 32--National Defense

            Subtitle A--Department of Defense
         I  Office of the Secretary of Defense (Parts 1--399)
         V  Department of the Army (Parts 400--699)
        VI  Department of the Navy (Parts 700--799)
       VII  Department of the Air Force (Parts 800--1099)
            Subtitle B--Other Regulations Relating to National 
                Defense
       XII  Defense Logistics Agency (Parts 1200--1299)
       XVI  Selective Service System (Parts 1600--1699)
       XIX  Central Intelligence Agency (Parts 1900--1999)
        XX  Information Security Oversight Office, National 
                Archives and Records Administration (Parts 2000--
                2099)
       XXI  National Security Council (Parts 2100--2199)
      XXIV  Office of Science and Technology Policy (Parts 2400--
                2499)
     XXVII  Office for Micronesian Status Negotiations (Parts 
                2700--2799)
    XXVIII  Office of the Vice President of the United States 
                (Parts 2800--2899)
      XXIX  Presidential Commission on the Assignment of Women in 
                the Armed Forces (Part 2900)

[[Page 649]]

               Title 33--Navigation and Navigable Waters

         I  Coast Guard, Department of Transportation (Parts 1--
                199)
        II  Corps of Engineers, Department of the Army (Parts 
                200--399)
        IV  Saint Lawrence Seaway Development Corporation, 
                Department of Transportation (Parts 400--499)

                          Title 34--Education

            Subtitle A--Office of the Secretary, Department of 
                Education (Parts 1--99)
            Subtitle B--Regulations of the Offices of the 
                Department of Education
         I  Office for Civil Rights, Department of Education 
                (Parts 100--199)
        II  Office of Elementary and Secondary Education, 
                Department of Education (Parts 200--299)
       III  Office of Special Education and Rehabilitative 
                Services, Department of Education (Parts 300--399)
        IV  Office of Vocational and Adult Education, Department 
                of Education (Parts 400--499)
         V  Office of Bilingual Education and Minority Languages 
                Affairs, Department of Education (Parts 500--599)
        VI  Office of Postsecondary Education, Department of 
                Education (Parts 600--699)
       VII  Office of Educational Research and Improvement, 
                Department of Education (Parts 700--799)
        XI  National Institute for Literacy (Parts 1100-1199)
            Subtitle C--Regulations Relating to Education
       XII  National Council on Disability (Parts 1200--1299)

                        Title 35--Panama Canal

         I  Panama Canal Regulations (Parts 1--299)

             Title 36--Parks, Forests, and Public Property

         I  National Park Service, Department of the Interior 
                (Parts 1--199)
        II  Forest Service, Department of Agriculture (Parts 200--
                299)
       III  Corps of Engineers, Department of the Army (Parts 
                300--399)
        IV  American Battle Monuments Commission (Parts 400--499)
         V  Smithsonian Institution (Parts 500--599)
       VII  Library of Congress (Parts 700--799)
      VIII  Advisory Council on Historic Preservation (Parts 800--
                899)
        IX  Pennsylvania Avenue Development Corporation (Parts 
                900--999)
        XI  Architectural and Transportation Barriers Compliance 
                Board (Parts 1100--1199)
       XII  National Archives and Records Administration (Parts 
                1200--1299)
       XIV  Assassination Records Review Board (Parts 1400-1499)

[[Page 650]]

             Title 37--Patents, Trademarks, and Copyrights

         I  Patent and Trademark Office, Department of Commerce 
                (Parts 1--199)
        II  Copyright Office, Library of Congress (Parts 200--299)
        IV  Assistant Secretary for Technology Policy, Department 
                of Commerce (Parts 400--499)
         V  Under Secretary for Technology, Department of Commerce 
                (Parts 500--599)

           Title 38--Pensions, Bonuses, and Veterans' Relief

         I  Department of Veterans Affairs (Parts 0--99)

                       Title 39--Postal Service

         I  United States Postal Service (Parts 1--999)
       III  Postal Rate Commission (Parts 3000--3099)

                  Title 40--Protection of Environment

         I  Environmental Protection Agency (Parts 1--799)
         V  Council on Environmental Quality (Parts 1500--1599)

          Title 41--Public Contracts and Property Management

            Subtitle B--Other Provisions Relating to Public 
                Contracts
        50  Public Contracts, Department of Labor (Parts 50-1--50-
                999)
        51  Committee for Purchase From People Who Are Blind or 
                Severely Disabled (Parts 51-1--51-99)
        60  Office of Federal Contract Compliance Programs, Equal 
                Employment Opportunity, Department of Labor (Parts 
                60-1--60-999)
        61  Office of the Assistant Secretary for Veterans 
                Employment and Training, Department of Labor 
                (Parts 61-1--61-999)
            Subtitle C--Federal Property Management Regulations 
                System
       101  Federal Property Management Regulations (Parts 101-1--
                101-99)
       105  General Services Administration (Parts 105-1--105-999)
       109  Department of Energy Property Management Regulations 
                (Parts 109-1--109-99)
       114  Department of the Interior (Parts 114-1--114-99)
       115  Environmental Protection Agency (Parts 115-1--115-99)
       128  Department of Justice (Parts 128-1--128-99)
            Subtitle D--Other Provisions Relating to Property 
                Management [Reserved]
            Subtitle E--Federal Information Resources Management 
                Regulations System
       201  Federal Information Resources Management Regulation 
                (Parts 201-1--201-99) [Reserved]
            Subtitle F--Federal Travel Regulation System
       301  Travel Allowances (Parts 301-1--301-99)
       302  Relocation Allowances (Parts 302-1--302-99)

[[Page 651]]

       303  Payment of Expenses Connected with the Death of 
                Certain Employees (Parts 303-1--303-2)
       304  Payment from a Non-Federal Source for Travel Expenses 
                (Parts 304-1--304-99)

                        Title 42--Public Health

         I  Public Health Service, Department of Health and Human 
                Services (Parts 1--199)
        IV  Health Care Financing Administration, Department of 
                Health and Human Services (Parts 400--499)
         V  Office of Inspector General-Health Care, Department of 
                Health and Human Services (Parts 1000--1999)

                   Title 43--Public Lands: Interior

            Subtitle A--Office of the Secretary of the Interior 
                (Parts 1--199)
            Subtitle B--Regulations Relating to Public Lands
         I  Bureau of Reclamation, Department of the Interior 
                (Parts 200--499)
        II  Bureau of Land Management, Department of the Interior 
                (Parts 1000--9999)
       III  Utah Reclamation Mitigation and Conservation 
                Commission (Parts 10000--10005)

             Title 44--Emergency Management and Assistance

         I  Federal Emergency Management Agency (Parts 0--399)
        IV  Department of Commerce and Department of 
                Transportation (Parts 400--499)

                       Title 45--Public Welfare

            Subtitle A--Department of Health and Human Services 
                (Parts 1--199)
            Subtitle B--Regulations Relating to Public Welfare
        II  Office of Family Assistance (Assistance Programs), 
                Administration for Children and Families, 
                Department of Health and Human Services (Parts 
                200--299)
       III  Office of Child Support Enforcement (Child Support 
                Enforcement Program), Administration for Children 
                and Families, Department of Health and Human 
                Services (Parts 300--399)
        IV  Office of Refugee Resettlement, Administration for 
                Children and Families Department of Health and 
                Human Services (Parts 400--499)
         V  Foreign Claims Settlement Commission of the United 
                States, Department of Justice (Parts 500--599)
        VI  National Science Foundation (Parts 600--699)
       VII  Commission on Civil Rights (Parts 700--799)
      VIII  Office of Personnel Management (Parts 800--899)

[[Page 652]]

         X  Office of Community Services, Administration for 
                Children and Families, Department of Health and 
                Human Services (Parts 1000--1099)
        XI  National Foundation on the Arts and the Humanities 
                (Parts 1100--1199)
       XII  ACTION (Parts 1200--1299)
      XIII  Office of Human Development Services, Department of 
                Health and Human Services (Parts 1300--1399)
       XVI  Legal Services Corporation (Parts 1600--1699)
      XVII  National Commission on Libraries and Information 
                Science (Parts 1700--1799)
     XVIII  Harry S. Truman Scholarship Foundation (Parts 1800--
                1899)
       XXI  Commission on Fine Arts (Parts 2100--2199)
      XXII  Christopher Columbus Quincentenary Jubilee Commission 
                (Parts 2200--2299)
     XXIII  Arctic Research Commission (Part 2301)
      XXIV  James Madison Memorial Fellowship Foundation (Parts 
                2400--2499)
       XXV  Corporation for National and Community Service (Parts 
                2500--2599)

                          Title 46--Shipping

         I  Coast Guard, Department of Transportation (Parts 1--
                199)
        II  Maritime Administration, Department of Transportation 
                (Parts 200--399)
        IV  Federal Maritime Commission (Parts 500--599)

                      Title 47--Telecommunication

         I  Federal Communications Commission (Parts 0--199)
        II  Office of Science and Technology Policy and National 
                Security Council (Parts 200--299)
       III  National Telecommunications and Information 
                Administration, Department of Commerce (Parts 
                300--399)

           Title 48--Federal Acquisition Regulations System

         1  Federal Acquisition Regulation (Parts 1--99)
         2  Department of Defense (Parts 200--299)
         3  Department of Health and Human Services (Parts 300--
                399)
         4  Department of Agriculture (Parts 400--499)
         5  General Services Administration (Parts 500--599)
         6  Department of State (Parts 600--699)
         7  United States Agency for International Development 
                (Parts 700--799)
         8  Department of Veterans Affairs (Parts 800--899)
         9  Department of Energy (Parts 900--999)
        10  Department of the Treasury (Parts 1000--1099)

[[Page 653]]

        12  Department of Transportation (Parts 1200--1299)
        13  Department of Commerce (Parts 1300--1399)
        14  Department of the Interior (Parts 1400--1499)
        15  Environmental Protection Agency (Parts 1500--1599)
        16  Office of Personnel Management Federal Employees 
                Health Benefits Acquisition Regulation (Parts 
                1600--1699)
        17  Office of Personnel Management (Parts 1700--1799)
        18  National Aeronautics and Space Administration (Parts 
                1800--1899)
        19  United States Information Agency (Parts 1900--1999)
        20  Nuclear Regulatory Commission (Parts 2000--2099)
        21  Office of Personnel Management, Federal Employees 
                Group Life Insurance Federal Acquisition 
                Regulation (Parts 2100--2199)
        23  Social Security Administration (Parts 2300--2399)
        24  Department of Housing and Urban Development (Parts 
                2400--2499)
        25  National Science Foundation (Parts 2500--2599)
        28  Department of Justice (Parts 2800--2899)
        29  Department of Labor (Parts 2900--2999)
        34  Department of Education Acquisition Regulation (Parts 
                3400--3499)
        35  Panama Canal Commission (Parts 3500--3599)
        44  Federal Emergency Management Agency (Parts 4400--4499)
        51  Department of the Army Acquisition Regulations (Parts 
                5100--5199)
        52  Department of the Navy Acquisition Regulations (Parts 
                5200--5299)
        53  Department of the Air Force Federal Acquisition 
                Regulation Supplement (Parts 5300--5399)
        54  Defense Logistics Agency, Department of Defense (Part 
                5452)
        57  African Development Foundation (Parts 5700--5799)
        61  General Services Administration Board of Contract 
                Appeals (Parts 6100--6199)
        63  Department of Transportation Board of Contract Appeals 
                (Parts 6300--6399)
        99  Cost Accounting Standards Board, Office of Federal 
                Procurement Policy, Office of Management and 
                Budget (Parts 9900--9999)

                       Title 49--Transportation

            Subtitle A--Office of the Secretary of Transportation 
                (Parts 1--99)
            Subtitle B--Other Regulations Relating to 
                Transportation
         I  Research and Special Programs Administration, 
                Department of Transportation (Parts 100--199)
        II  Federal Railroad Administration, Department of 
                Transportation (Parts 200--299)

[[Page 654]]

       III  Federal Highway Administration, Department of 
                Transportation (Parts 300--399)
        IV  Coast Guard, Department of Transportation (Parts 400--
                499)
         V  National Highway Traffic Safety Administration, 
                Department of Transportation (Parts 500--599)
        VI  Federal Transit Administration, Department of 
                Transportation (Parts 600--699)
       VII  National Railroad Passenger Corporation (AMTRAK) 
                (Parts 700--799)
      VIII  National Transportation Safety Board (Parts 800--999)
         X  Surface Transportation Board, Department of 
                Transportation (Parts 1000--1399)

                   Title 50--Wildlife and Fisheries

         I  United States Fish and Wildlife Service, Department of 
                the Interior (Parts 1--199)
        II  National Marine Fisheries Service, National Oceanic 
                and Atmospheric Administration, Department of 
                Commerce (Parts 200--299)
       III  International Fishing and Related Activities (Parts 
                300--399)
        IV  Joint Regulations (United States Fish and Wildlife 
                Service, Department of the Interior and National 
                Marine Fisheries Service, National Oceanic and 
                Atmospheric Administration, Department of 
                Commerce); Endangered Species Committee 
                Regulations (Parts 400--499)
         V  Marine Mammal Commission (Parts 500--599)
        VI  Fishery Conservation and Management, National Oceanic 
                and Atmospheric Administration, Department of 
                Commerce (Parts 600--699)

                      CFR Index and Finding Aids

            Subject/Agency Index
            List of Agency Prepared Indexes
            Parallel Tables of Statutory Authorities and Rules
            Acts Requiring Publication in the Federal Register
            List of CFR Titles, Chapters, Subchapters, and Parts
            Alphabetical List of Agencies Appearing in the CFR



[[Page 655]]





           Alphabetical List of Agencies Appearing in the CFR




                   (Revised as of September 30, 1997)

                                                  CFR Title, Subtitle or 
                     Agency                               Chapter

ACTION                                            45, XII
Administrative Committee of the Federal Register  1, I
Advanced Research Projects Agency                 32, I
Advisory Commission on Intergovernmental          5, VII
     Relations
Advisory Committee on Federal Pay                 5, IV
Advisory Council on Historic Preservation         36, VIII
African Development Foundation                    22, XV
  Federal Acquisition Regulation                  48, 57
Agency for International Development, United      22, II
     States
  Federal Acquisition Regulation                  48, 7
Agricultural Marketing Service                    7, I, IX, X, XI
Agricultural Research Service                     7, V
Agriculture Department
  Agricultural Marketing Service                  7, I, IX, X, XI
  Agricultural Research Service                   7, V
  Animal and Plant Health Inspection Service      7, III; 9, I
  Chief Financial Officer, Office of              7, XXX
  Commodity Credit Corporation                    7, XIV
  Cooperative State Research, Education, and      7, XXXIV
       Extension Service
  Economic Research Service                       7, XXXVII
  Energy, Office of                               7, XXIX
  Environmental Quality, Office of                7, XXXI
  Farm Service Agency                             7, VII, XVIII
  Federal Acquisition Regulation                  48, 4
  Federal Crop Insurance Corporation              7, IV
  Food and Consumer Service                       7, II
  Food Safety and Inspection Service              9, III
  Foreign Agricultural Service                    7, XV
  Forest Service                                  36, II
  Grain Inspection, Packers and Stockyards        7, VIII; 9, II
       Administration
  Information Resources Management, Office of     7, XXVII
  Inspector General, Office of                    7, XXVI
  National Agricultural Library                   7, XLI
  National Agricultural Statistics Service        7, XXXVI
  Natural Resources Conservation Service          7, VI
  Operations, Office of                           7, XXVIII
  Rural Business-Cooperative Service              7, XVIII, XLII
  Rural Development Administration                7, XLII
  Rural Housing Service                           7, XVIII, XXXV
  Rural Telephone Bank                            7, XVI
  Rural Utilities Service                         7, XVII, XVIII, XLII
  Secretary of Agriculture, Office of             7, Subtitle A
  Transportation, Office of                       7, XXXIII
  World Agricultural Outlook Board                7, XXXVIII
Air Force Department                              32, VII
  Federal Acquisition Regulation Supplement       48, 53
Alaska Natural Gas Transportation System, Office  10, XV
     of the Federal Inspector
Alcohol, Tobacco and Firearms, Bureau of          27, I
AMTRAK                                            49, VII
American Battle Monuments Commission              36, IV
American Indians, Office of the Special Trustee   25, VII

[[Page 656]]

Animal and Plant Health Inspection Service        7, III; 9, I
Appalachian Regional Commission                   5, IX
Architectural and Transportation Barriers         36, XI
     Compliance Board
Arctic Research Commission                        45, XXIII
Armed Forces Retirement Home                      5, XI
Arms Control and Disarmament Agency, United       22, VI
     States
Army Department                                   32, V
  Engineers, Corps of                             33, II; 36, III
  Federal Acquisition Regulation                  48, 51
Assassination Records Review Board                36, XIV
Benefits Review Board                             20, VII
Bilingual Education and Minority Languages        34, V
     Affairs, Office of
Blind or Severely Disabled, Committee for         41, 51
     Purchase From People Who Are
Board for International Broadcasting              22, XIII
Census Bureau                                     15, I
Central Intelligence Agency                       32, XIX
Chief Financial Officer, Office of                7, XXX
Child Support Enforcement, Office of              45, III
Children and Families, Administration for         45, II, III, IV, X
Christopher Columbus Quincentenary Jubilee        45, XXII
     Commission
Civil Rights, Commission on                       45, VII
Civil Rights, Office for                          34, I
Coast Guard                                       33, I; 46, I; 49, IV
Commerce Department                               44, IV
  Census Bureau                                   15, I`
  Economic Affairs, Under Secretary               37, V
  Economic Analysis, Bureau of                    15, VIII
  Economic Development Administration             13, III
  Emergency Management and Assistance             44, IV
  Export Administration, Bureau of                15, VII
  Federal Acquisition Regulation                  48, 13
  Fishery Conservation and Management             50, VI
  Foreign-Trade Zones Board                       15, IV
  International Trade Administration              15, III; 19, III
  National Institute of Standards and Technology  15, II
  National Marine Fisheries Service               50, II, IV
  National Oceanic and Atmospheric                15, IX; 50, II, III, IV, 
       Administration                             VI
  National Telecommunications and Information     15, XXIII; 47, III
       Administration
  National Weather Service                        15, IX
  Patent and Trademark Office                     37, I
  Productivity, Technology and Innovation,        37, IV
       Assistant Secretary for
  Secretary of Commerce, Office of                15, Subtitle A
  Technology, Under Secretary for                 37, V
  Technology Administration                       15, XI
  Technology Policy, Assistant Secretary for      37, IV
Commercial Space Transportation                   14, III
Commodity Credit Corporation                      7, XIV
Commodity Futures Trading Commission              5, XLI; 17, I
Community Planning and Development, Office of     24, V, VI
     Assistant Secretary for
Community Services, Office of                     45, X
Comptroller of the Currency                       12, I
Construction Industry Collective Bargaining       29, IX
     Commission
Consumer Product Safety Commission                5, LXXI; 16, II
Cooperative State Research, Education, and        7, XXXIV
     Extension Service
Copyright Office                                  37, II
Cost Accounting Standards Board                   48, 99
Council on Environmental Quality                  40, V
Customs Service, United States                    19, I
Defense Contract Audit Agency                     32, I
Defense Department                                5, XXVI; 32, Subtitle A
  Advanced Research Projects Agency               32, I
  Air Force Department                            32, VII

[[Page 657]]

  Army Department                                 32, V; 33, II; 36, III, 
                                                  48, 51
  Defense Intelligence Agency                     32, I
  Defense Logistics Agency                        32, I, XII; 48, 54
  Defense Mapping Agency                          32, I
  Engineers, Corps of                             33, II; 36, III
  Federal Acquisition Regulation                  48, 2
  Navy Department                                 32, VI; 48, 52
  Secretary of Defense, Office of                 32, I
Defense Contract Audit Agency                     32, I
Defense Intelligence Agency                       32, I
Defense Logistics Agency                          32, XII; 48, 54
Defense Mapping Agency                            32, I
Defense Nuclear Facilities Safety Board           10, XVII
Delaware River Basin Commission                   18, III
Drug Enforcement Administration                   21, II
East-West Foreign Trade Board                     15, XIII
Economic Affairs, Under Secretary                 37, V
Economic Analysis, Bureau of                      15, VIII
Economic Development Administration               13, III
Economic Research Service                         7, XXXVII
Education, Department of                          5, LIII
  Bilingual Education and Minority Languages      34, V
       Affairs, Office of
  Civil Rights, Office for                        34, I
  Educational Research and Improvement, Office    34, VII
       of
  Elementary and Secondary Education, Office of   34, II
  Federal Acquisition Regulation                  48, 34
  Postsecondary Education, Office of              34, VI
  Secretary of Education, Office of               34, Subtitle A
  Special Education and Rehabilitative Services,  34, III
       Office of
  Vocational and Adult Education, Office of       34, IV
Educational Research and Improvement, Office of   34, VII
Elementary and Secondary Education, Office of     34, II
Employees' Compensation Appeals Board             20, IV
Employees Loyalty Board                           5, V
Employment and Training Administration            20, V
Employment Standards Administration               20, VI
Endangered Species Committee                      50, IV
Energy, Department of                             5, XXIII; 10, II, III, X
  Federal Acquisition Regulation                  48, 9
  Federal Energy Regulatory Commission            5, XXIV; 18, I
  Property Management Regulations                 41, 109
Energy, Office of                                 7, XXIX
Engineers, Corps of                               33, II; 36, III
Engraving and Printing, Bureau of                 31, VI
Enrichment Corporation, United States             10, XI
Environmental Protection Agency                   5, LIV; 40, I
  Federal Acquisition Regulation                  48, 15
  Property Management Regulations                 41, 115
Environmental Quality, Office of                  7, XXXI
Equal Employment Opportunity Commission           5, LXII; 29, XIV
Equal Opportunity, Office of Assistant Secretary  24, I
     for
Executive Office of the President                 3, I
  Administration, Office of                       5, XV
  Environmental Quality, Council on               40, V
  Management and Budget, Office of                25, III, LXXVII; 48, 99
  National Drug Control Policy, Office of         21, III
  National Security Council                       32, XXI; 47, 2
  Presidential Documents                          3
  Science and Technology Policy, Office of        32, XXIV; 47, II
  Trade Representative, Office of the United      15, XX
       States
Export Administration, Bureau of                  15, VII
Export-Import Bank of the United States           5, LII; 12, IV
Family Assistance, Office of                      45, II
Farm Credit Administration                        5, XXXI; 12, VI
Farm Credit System Insurance Corporation          5, XXX; 12, XIV

[[Page 658]]

Farm Service Agency                               7, VII, XVIII
Federal Acquisition Regulation                    48, 1
Federal Aviation Administration                   14, I
  Commercial Space Transportation                 14, III
Federal Claims Collection Standards               4, II
Federal Communications Commission                 5, XXIX; 47, I
Federal Contract Compliance Programs, Office of   41, 60
Federal Crop Insurance Corporation                7, IV
Federal Deposit Insurance Corporation             5, XXII; 12, III
Federal Election Commission                       11, I
Federal Emergency Management Agency               44, I
  Federal Acquisition Regulation                  48, 44
Federal Employees Group Life Insurance Federal    48, 21
     Acquisition Regulation
Federal Employees Health Benefits Acquisition     48, 16
     Regulation
Federal Energy Regulatory Commission              5, XXIV; 18, I
Federal Financial Institutions Examination        12, XI
     Council
Federal Financing Bank                            12, VIII
Federal Highway Administration                    23, I, II; 49, III
Federal Home Loan Mortgage Corporation            1, IV
Federal Housing Enterprise Oversight Office       12, XVII
Federal Housing Finance Board                     12, IX
Federal Inspector for the Alaska Natural Gas      10, XV
     Transportation System, Office of
Federal Labor Relations Authority, and General    5, XIV; 22, XIV
     Counsel of the Federal Labor Relations 
     Authority
Federal Law Enforcement Training Center           31, VII
Federal Maritime Commission                       46, IV
Federal Mediation and Conciliation Service        29, XII
Federal Mine Safety and Health Review Commission  5, LXXIV; 29, XXVII
Federal Pay, Advisory Committee on                5, IV
Federal Prison Industries, Inc.                   28, III
Federal Procurement Policy Office                 48, 99
Federal Property Management Regulations           41, 101
Federal Property Management Regulations System    41, Subtitle C
Federal Railroad Administration                   49, II
Federal Register, Administrative Committee of     1, I
Federal Register, Office of                       1, II
Federal Reserve System                            12, II
  Board of Governors                              5, LVIII
Federal Retirement Thrift Investment Board        5, VI, LXXVI
Federal Service Impasses Panel                    5, XIV
Federal Trade Commission                          5, XLVII; 16, I
Federal Transit Administration                    49, VI
Federal Travel Regulation System                  41, Subtitle F
Fine Arts, Commission on                          45, XXI
Fiscal Service                                    31, II
Fish and Wildlife Service, United States          50, I, IV
Fishery Conservation and Management               50, VI
Food and Drug Administration                      21, I
Food and Consumer Service                         7, II
Food Safety and Inspection Service                9, III
Foreign Agricultural Service                      7, XV
Foreign Assets Control, Office of                 31, V
Foreign Claims Settlement Commission of the       45, V
     United States
Foreign Service Grievance Board                   22, IX
Foreign Service Impasse Disputes Panel            22, XIV
Foreign Service Labor Relations Board             22, XIV
Foreign-Trade Zones Board                         15, IV
Forest Service                                    36, II
General Accounting Office                         4, I, II
General Services Administration                   5, LVII
  Contract Appeals, Board of                      48, 61
  Federal Acquisition Regulation                  48, 5
  Federal Property Management Regulations System  41, 101, 105
  Federal Travel Regulation System                41, Subtitle F
  Payment From a Non-Federal Source for Travel    41, 304
     Expenses
[[Page 659]]

  Payment of Expenses Connected With the Death    41, 303
       of Certain Employees
  Relocation Allowances                           41, 302
  Travel Allowances                               41, 301
Geological Survey                                 30, IV
Government Ethics, Office of                      5, XVI
Government National Mortgage Association          24, III
Grain Inspection, Packers and Stockyards          7, VIII; 9, II
     Administration
Great Lakes Pilotage                              46, III
Harry S. Truman Scholarship Foundation            45, XVIII
Health and Human Services, Department of          5, XLV; 45, Subtitle A
  Child Support Enforcement, Office of            45, III
  Children and Families, Administration for       45, II, III, IV, X
  Community Services, Office of                   45, X
  Family Assistance, Office of                    45, II
  Federal Acquisition Regulation                  48, 3
  Food and Drug Administration                    21, I
  Health Care Financing Administration            42, IV
  Human Development Services, Office of           45, XIII
  Indian Health Service                           25, V
  Inspector General (Health Care), Office of      42, V
  Public Health Service                           42, I
  Refugee Resettlement, Office of                 45, IV
Health Care Financing Administration              42, IV
Housing and Urban Development, Department of      5, LXV; 24, Subtitle B
  Community Planning and Development, Office of   24, V, VI
       Assistant Secretary for
  Equal Opportunity, Office of Assistant          24, I
       Secretary for
  Federal Acquisition Regulation                  48, 24
  Federal Housing Enterprise Oversight, Office    12, XVII
       of
  Government National Mortgage Association        24, III
  Housing--Federal Housing Commissioner, Office   24, II, VIII, X, XX
       of Assistant Secretary for
  Inspector General, Office of                    24, XII
  Public and Indian Housing, Office of Assistant  24, IX
       Secretary for
  Secretary, Office of                            24, Subtitle A, VII
Housing--Federal Housing Commissioner, Office of  24, II, VIII, X, XX
     Assistant Secretary for
Human Development Services, Office of             45, XIII
Immigration and Naturalization Service            8, I
Independent Counsel, Office of                    28, VII
Indian Affairs, Bureau of                         25, I, V
Indian Affairs, Office of the Assistant           25, VI
     Secretary
Indian Arts and Crafts Board                      25, II
Indian Health Service                             25, V
Information Agency, United States                 22, V
  Federal Acquisition Regulation                  48, 19
Information Resources Management, Office of       7, XXVII
Information Security Oversight Office, National   32, XX
     Archives and Records Administration
Inspector General
  Agriculture Department                          7, XXVI
  Health and Human Services Department            42, V
  Housing and Urban Development Department        24, XII
Institute of Peace, United States                 22, XVII
Inter-American Foundation                         5, LXIII; 22, X
Intergovernmental Relations, Advisory Commission  5, VII
     on
Interior Department
  American Indians, Office of the Special         25, VII
       Trustee
  Endangered Species Committee                    50, IV
  Federal Acquisition Regulation                  48, 14
  Federal Property Management Regulations System  41, 114
  Fish and Wildlife Service, United States        50, I, IV
  Geological Survey                               30, IV
  Indian Affairs, Bureau of                       25, I, V
  Indian Affairs, Office of the Assistant         25, VI
       Secretary
  Indian Arts and Crafts Board                    25, II

[[Page 660]]

  Land Management, Bureau of                      43, II
  Minerals Management Service                     30, II
  Mines, Bureau of                                30, VI
  National Indian Gaming Commission               25, III
  National Park Service                           36, I
  Reclamation, Bureau of                          43, I
  Secretary of the Interior, Office of            43, Subtitle A
  Surface Mining and Reclamation Appeals, Board   30, III
       of
  Surface Mining Reclamation and Enforcement,     30, VII
       Office of
Internal Revenue Service                          26, I
International Boundary and Water Commission,      22, XI
     United States and Mexico, United States 
     Section
International Development, United States Agency   22, II
     for
  Federal Acquisition Regulation                  48, 7
International Development Cooperation Agency,     22, XII
     United States
  International Development, United States        22, II; 48, 7
       Agency for
  Overseas Private Investment Corporation         5, XXXIII; 22, VII
International Fishing and Related Activities      50, III
International Investment, Office of               31, VIII
International Joint Commission, United States     22, IV
     and Canada
International Organizations Employees Loyalty     5, V
     Board
International Trade Administration                15, III; 19, III
International Trade Commission, United States     19, II
Interstate Commerce Commission                    5, XL
James Madison Memorial Fellowship Foundation      45, XXIV
Japan-United States Friendship Commission         22, XVI
Joint Board for the Enrollment of Actuaries       20, VIII
Justice Department                                5, XXVIII; 28, I
  Drug Enforcement Administration                 21, II
  Federal Acquisition Regulation                  48, 28
  Federal Claims Collection Standards             4, II
  Federal Prison Industries, Inc.                 28, III
  Foreign Claims Settlement Commission of the     45, V
       United States
  Immigration and Naturalization Service          8, I
  Offices of Independent Counsel                  28, VI
  Prisons, Bureau of                              28, V
  Property Management Regulations                 41, 128
Labor Department                                  5, XLII
  Benefits Review Board                           20, VII
  Employees' Compensation Appeals Board           20, IV
  Employment and Training Administration          20, V
  Employment Standards Administration             20, VI
  Federal Acquisition Regulation                  48, 29
  Federal Contract Compliance Programs, Office    41, 60
       of
  Federal Procurement Regulations System          41, 50
  Labor-Management Standards, Office of           29, II, IV
  Mine Safety and Health Administration           30, I
  Occupational Safety and Health Administration   29, XVII
  Pension and Welfare Benefits Administration     29, XXV
  Public Contracts                                41, 50
  Secretary of Labor, Office of                   29, Subtitle A
  Veterans' Employment and Training, Office of    41, 61; 20, IX
       the Assistant Secretary for
  Wage and Hour Division                          29, V
  Workers' Compensation Programs, Office of       20, I
Labor-Management Standards, Office of             29, II, IV
Land Management, Bureau of                        43, II
Legal Services Corporation                        45, XVI
Library of Congress                               36, VII
  Copyright Office                                37, II
Management and Budget, Office of                  5, III, LXXVII; 48, 99
Marine Mammal Commission                          50, V
Maritime Administration                           46, II
Merit Systems Protection Board                    5, II
Micronesian Status Negotiations, Office for       32, XXVII

[[Page 661]]

Mine Safety and Health Administration             30, I
Minerals Management Service                       30, II
Mines, Bureau of                                  30, VI
Minority Business Development Agency              15, XIV
Miscellaneous Agencies                            1, IV
Monetary Offices                                  31, I
National Aeronautics and Space Administration     5, LIX; 14, V
  Federal Acquisition Regulation                  48, 18
National Agricultural Library                     7, XLI
National Agricultural Statistics Service          7, XXXVI
National Archives and Records Administration      5, LXVI; 36, XII
  Information Security Oversight Office           32, XX
National Bureau of Standards                      15, II
National Capital Planning Commission              1, IV
National Commission for Employment Policy         1, IV
National Commission on Libraries and Information  45, XVII
     Science
National and Community Service, Corporation for   45, XXV
National Council on Disability                    34, XII
National Credit Union Administration              12, VII
National Drug Control Policy, Office of           21, III
National Foundation on the Arts and the           45, XI
     Humanities
National Highway Traffic Safety Administration    23, II, III; 49, V
National Indian Gaming Commission                 25, III
National Institute for Literacy                   34, XI
National Institute of Standards and Technology    15, II
National Labor Relations Board                    5, LXI; 29, I
National Marine Fisheries Service                 50, II, IV
National Mediation Board                          29, X
National Oceanic and Atmospheric Administration   15, IX; 50, II, III, IV, 
                                                  VI
National Park Service                             36, I
National Railroad Adjustment Board                29, III
National Railroad Passenger Corporation (AMTRAK)  49, VII
National Science Foundation                       5, XLIII; 45, VI
  Federal Acquisition Regulation                  48, 25
National Security Council                         32, XXI
National Security Council and Office of Science   47, II
     and Technology Policy
National Telecommunications and Information       15, XXIII; 47, III
     Administration
National Transportation Safety Board              49, VIII
National Weather Service                          15, IX
Natural Resources Conservation Service            7, VI
Navajo and Hopi Indian Relocation, Office of      25, IV
Navy Department                                   32, VI
  Federal Acquisition Regulation                  48, 52
Neighborhood Reinvestment Corporation             24, XXV
Northeast Dairy Compact Commission                7, XIII
Nuclear Regulatory Commission                     5, XLVIII; 10, I
  Federal Acquisition Regulation                  48, 20
Occupational Safety and Health Administration     29, XVII
Occupational Safety and Health Review Commission  29, XX
Offices of Independent Counsel                    28, VI
Operations Office                                 7, XXVIII
Overseas Private Investment Corporation           5, XXXIII; 22, VII
Panama Canal Commission                           48, 35
Panama Canal Regulations                          35, I
Patent and Trademark Office                       37, I
Payment From a Non-Federal Source for Travel      41, 304
     Expenses
Payment of Expenses Connected With the Death of   41, 303
     Certain Employees
Peace Corps                                       22, III
Pennsylvania Avenue Development Corporation       36, IX
Pension and Welfare Benefits Administration       29, XXV
Pension Benefit Guaranty Corporation              29, XL
Personnel Management, Office of                   5, I, XXXV; 45, VIII
  Federal Acquisition Regulation                  48, 17
  Federal Employees Group Life Insurance Federal  48, 21
     Acquisition Regulation
[[Page 662]]

  Federal Employees Health Benefits Acquisition   48, 16
       Regulation
Postal Rate Commission                            5, XLVI; 39, III
Postal Service, United States                     5, LX; 39, I
Postsecondary Education, Office of                34, VI
President's Commission on White House             1, IV
     Fellowships
Presidential Commission on the Assignment of      32, XXIX
     Women in the Armed Forces
Presidential Documents                            3
Prisons, Bureau of                                28, V
Productivity, Technology and Innovation,          37, IV
     Assistant Secretary
Public Contracts, Department of Labor             41, 50
Public and Indian Housing, Office of Assistant    24, IX
     Secretary for
Public Health Service                             42, I
Railroad Retirement Board                         20, II
Reclamation, Bureau of                            43, I
Refugee Resettlement, Office of                   45, IV
Regional Action Planning Commissions              13, V
Relocation Allowances                             41, 302
Research and Special Programs Administration      49, I
Rural Business-Cooperative Service                7, XVIII, XLII
Rural Development Administration                  7, XLII
Rural Housing Service                             7, XVIII, XXXV
Rural Telephone Bank                              7, XVI
Rural Utilities Service                           7, XVII, XVIII, XLII
Saint Lawrence Seaway Development Corporation     33, IV
Science and Technology Policy, Office of          32, XXIV
Science and Technology Policy, Office of, and     47, II
     National Security Council
Secret Service                                    31, IV
Securities and Exchange Commission                17, II
Selective Service System                          32, XVI
Small Business Administration                     13, I
Smithsonian Institution                           36, V
Social Security Administration                    20, III; 48, 23
Soldiers' and Airmen's Home, United States        5, XI
Special Counsel, Office of                        5, VIII
Special Education and Rehabilitative Services,    34, III
     Office of
State Department                                  22, I
  Federal Acquisition Regulation                  48, 6
Surface Mining and Reclamation Appeals, Board of  30, III
Surface Mining Reclamation and Enforcement,       30, VII
     Office of
Surface Transportation Board                      49, X
Susquehanna River Basin Commission                18, VIII
Technology Administration                         15, XI
Technology Policy, Assistant Secretary for        37, IV
Technology, Under Secretary for                   37, V
Tennessee Valley Authority                        5, LXIX; 18, XIII
Thrift Depositor Protection Oversight Board       12, XV
Thrift Supervision Office, Department of the      12, V
     Treasury
Trade Representative, United States, Office of    15, XX
Transportation, Department of                     5, L
  Coast Guard                                     33, I; 46, I; 49, IV
  Commercial Space Transportation                 14, III
  Contract Appeals, Board of                      48, 63
  Emergency Management and Assistance             44, IV
  Federal Acquisition Regulation                  48, 12
  Federal Aviation Administration                 14, I
  Federal Highway Administration                  23, I, II; 49, III
  Federal Railroad Administration                 49, II
  Federal Transit Administration                  49, VI
  Maritime Administration                         46, II
  National Highway Traffic Safety Administration  23, II, III; 49, V
  Research and Special Programs Administration    49, I
  Saint Lawrence Seaway Development Corporation   33, IV
  Secretary of Transportation, Office of          14, II; 49, Subtitle A
  Surface Transportation Board                    49, X

[[Page 663]]

Transportation, Office of                         7, XXXIII
Travel Allowances                                 41, 301
Treasury Department                               5, XXI; 17, IV
  Alcohol, Tobacco and Firearms, Bureau of        27, I
  Community Development Financial Institutions    12, XVIII
       Fund
  Comptroller of the Currency                     12, I
  Customs Service, United States                  19, I
  Engraving and Printing, Bureau of               31, VI
  Federal Acquisition Regulation                  48, 10
  Federal Law Enforcement Training Center         31, VII
  Fiscal Service                                  31, II
  Foreign Assets Control, Office of               31, V
  Internal Revenue Service                        26, I
  International Investment, Office of             31, VIII
  Monetary Offices                                31, I
  Secret Service                                  31, IV
  Secretary of the Treasury, Office of            31, Subtitle A
  Thrift Supervision, Office of                   12, V
Truman, Harry S. Scholarship Foundation           45, XVIII
United States and Canada, International Joint     22, IV
     Commission
United States and Mexico, International Boundary  22, XI
     and Water Commission, United States Section
United States Enrichment Corporation              10, XI
Utah Reclamation Mitigation and Conservation      43, III
     Commission
Veterans Affairs Department                       38, I
  Federal Acquisition Regulation                  48, 8
Veterans' Employment and Training, Office of the  41, 61; 20, IX
     Assistant Secretary for
Vice President of the United States, Office of    32, XXVIII
Vocational and Adult Education, Office of         34, IV
Wage and Hour Division                            29, V
Water Resources Council                           18, VI
Workers' Compensation Programs, Office of         20, I
World Agricultural Outlook Board                  7, XXXVIII

[[Page 665]]



List of CFR Sections Affected



All changes in this volume of the Code of Federal Regulations which were 
made by documents published in the Federal Register since January 1, 
1986, are enumerated in the following list. Entries indicate the nature 
of the changes effected. Page numbers refer to Federal Register pages. 
The user should consult the entries for chapters and parts as well as 
sections for revisions.
For the period before January 1, 1986, see the ``List of CFR Sections 
Affected, 1973-1985,'' published in four separate volumes.

                                  1986

48 CFR
                                                                   51 FR
                                                                    Page
Chapter 7
702.170-3  (a) amended.............................................20651
702.170-10  (a) amended............................................20651
    (a) revised....................................................41106
705  Subchapter assignment; editorial note..........................6004
    Authority citation revised.....................................42844
705.202  Revised...................................................42845
706  Subchapter assignment; editorial note..........................6004
    Authority citation revised.....................................42844
706.201-70 (Subpart 706.2)  Removed................................42845
706.501 (Subpart 706.5)  Amended...................................11449
716  Revised.......................................................11450
725.703  Revised...................................................34985
725.704  Amended...................................................11450
731.109  Amended...................................................20651
731.205-6  (b)(2) amended..........................................20651
731.371  (a) amended...............................................20651
731.770  (a) amended...............................................20651
737.200--737.272 (Subpart 737.2)  Heading revised..................34985
752.200  Amended...................................................11450
    Corrected......................................................12706
752.232-7  Added...................................................11450
752.7002  Amended..................................................11450
    Correctly designated...........................................12706
    (d) amended....................................................20651
    Amended........................................................34985
752.7004  Amended..................................................20652
752.7016  Amended..................................................34985
752.7028  Amended..................................................11450
    Correctly designated...........................................12706
Chapter 7  Appendix D revised......................................15268
    Appendixes B, C, F, G, and H amended...........................20652
    Appendix D amended.............................................42844
Chapter 8
801.201-70  Removed; interim.......................................23065
801.602  (a) introductory text amended; interim....................23065
801.602-70  (a)(1) amended; interim................................23066
801.602-72  (c) amended; interim...................................23066
802.100  Revised; interim..........................................23066
805  Subchapter assignment; editorial note..........................6004
805.202  Revised; interim..........................................23066
805.207  (a) amended; interim......................................23066
806  Added; interim................................................23066
808.001  (b) amended; interim......................................23068
808.404-1  Existing text designated as (a); (b) added..............19350
808.404-3  Revised.................................................19350
813.103 (Subpart 813.1)  Added; interim............................23068
814  Heading revised; interim......................................23068
814.103--814.104-70 (Subpart 814.1)  Heading revised; interim......23068
814.103-1  Revised; interim........................................23068
814.201  (f)(3) revised; interim...................................23068
814.203-1  (b) revised; interim....................................23068
814.203-2  Removed; interim........................................23068
814.205-1  Amended; interim........................................23068
814.205-2  Amended; interim........................................23068
814.404-1  Existing text designated as (a); (b) added; interim.....23068

[[Page 666]]

814.407-1  (c) and (d) removed; interim............................23068
814.407-8  Removed; interim........................................23068
815.103--815.104 (Subpart 815.1)  Removed; interim.................23069
815.200--815.215 (Subpart 815.2)  Removed; interim.................23069
815.502--815.506-1 (Subpart 815.5)  Added...........................6005
815.805-5  (c)(2) revised; interim.................................23069
815.7001--815.7002 (Subpart 815.70)  Added; interim................23069
819.202-70  (m) amended; interim...................................23070
833  Revised; interim..............................................23070
833.212  (b) (2) through (5) correctly revised.....................44179
836.302--836.371 (Subpart 836.3)  Heading amended; interim.........23072
842.000  Amended; interim..........................................23072
846.403  (b) amended...............................................37027
846.408-70  (a) amended; (b) and (c) redesignated as (c) and (d); 
        new (c) amended; new (b) added.............................37027
846.408-71  (a) amended............................................37028
852.233-2  Added; interim..........................................23072
852.236-88  Introductory text, (a) introductory text, and (b) 
        introductory text revised; (a) text amended; interim.......23073
Chapter 9
905  Subchapter assignment; editorial note..........................6004
906  Subchapter assignment; editorial note..........................6004
914.407-8  Removed; eff. 11-3-86...................................31336
914.407-70  Removed; eff. 11-3-86..................................31336
933  Revised; eff. 11-3-86.........................................31336
952.233-2  Added; eff. 11-3-86.....................................31339
970  Revised.......................................................43926
970.3102-17  (c) added.............................................43926
970.4406  Revised; eff. 11-3-86....................................31339
970.5204-13  (e)(35) added.........................................43926
970.5204-14  (e)(33) added.........................................43926
Chapter 10
1033.270  Corrected.................................................6741
Chapter 13
1301.101  Amended..................................................15329
1301.104-3  (b) Revised............................................15329
1301.201-1  Revised................................................15329
1301.301  (b) revision confirmed....................................1377
    (c) amended....................................................15329
1301.402  Amended..................................................15329
1301.501  Amended..................................................15329
1301.601-70  Amended...............................................15329
1301.601-71  Amended...............................................15330
1302.1-1  Amendment confirmed.......................................1377
    Amended........................................................15330
1304  Addition confirmed............................................1377
1305--1309 (Subchapter B)  Heading revision confirmed...............1377
1306  Addition confirmed............................................1377
1306.303  Added....................................................15330
1306.303-1  Added..................................................15330
1309.106--1309.106-70  (Subpart 1309.1)  Added.....................15330
1314  Heading revision confirmed....................................1377
1314.401-1  Addition confirmed......................................1377
1314.407-8  Removed................................................15331
1315.307 (Subpart 1315.3)  Removal confirmed........................1377
1315.608  Addition confirmed........................................1377
1319.202-2  Addition confirmed......................................1377
1319.705-5 (Subpart 1319.7)  Addition confirmed.....................1377
1319.7001--1319.7003 (Subpart 1319.70)  Added......................15331
1331.205-32  Revision confirmed.....................................1377
1333  Heading revised..............................................15331
1333.102--1333.106 (Subpart 1333.1)  Added.........................15331
1333.209--1333.213 (Subpart 1333.2)  Added.........................15332
1337.205  Revision confirmed........................................1377
1349  Added........................................................15332
1352.219-1--1352.233-2 (Subpart 1352.2)  Added.....................15333
1353.204-2  Revision confirmed......................................1377
1353.213  Addition confirmed........................................1377
1353.232  Revision confirmed........................................1377
1353  Appendix A amendment confirmed (not published in CFR).........1377
Chapter 14
1401.301  (a) and (b) amended......................................41965
1401.303  Heading revised..........................................41965
1405  Added........................................................41965
1406  Added........................................................41965
1414  Heading revised..............................................41965
1414.404  Added....................................................41965
1414.404-1  Added..................................................41965

[[Page 667]]

1414.407-8  Revised; final..........................................8830
1415.608  Added....................................................41965
1415.902  (d) revised..............................................41965
1415.905  (b) amended..............................................41965
1415.905-1  (a) introductory text, (3), and (5) amended; (a) (4) 
        and (5) redesignated as (a) (5) and (4)....................41965
1415.905-70  (b)(1) amended........................................41965
1419.705-6  Added..................................................41966
1420.102  Amended..................................................41966
1428.301  Amended..................................................41966
1433  Heading revised; final........................................8830
1433.003  Redesignated as 1433.203 and (a) amended; final...........8830
1433.003-70  Redesignated as 1433.203-70; final.....................8830
1433.011  Redesignated as 1433.211 and amended; final...............8830
1433.012  Redesignated as 1433.212; final...........................8830
1433.014  Redesignated as 1433.214; final...........................8830
1433.102--1433.106 (Subpart 1433.1)  Added; final...................8830
1433.203--1433.214 (Subpart 1433.2)  Heading added; final...........8830
1433.203  Redesignated from 1433.003 and (a) amended; final.........8830
1433.203-70  Redesignated from 1433.003-70; final...................8830
1433.211  Redesignated from 1433.011 and amended; final.............8830
1433.212  Redesignated from 1433.012; final.........................8830
1433.214  Redesignated from 1433.014; final.........................8830
1437.7001  Amended.................................................41966
1437.7002  (a) amended.............................................41966
1452.228-70  Heading revised; clause amended.......................41966
1452.233-2  Added; final............................................8831
1453.219-73  Added.................................................41966
1453.303-DI-1920  Revised..........................................41966
1453.303-70  Revised...............................................41968
1453.303-71  Added.................................................41969

                                  1987

48 CFR
                                                                   52 FR
                                                                    Page
Chapter 7
Appendix J added....................................................2354
    Appendix D amended..............................................4145
    Appendix G amended..............................................4146
    Appendix F amended..............................................6160
    Appendixes D and J amended.....................................11075
    Appendix D amended.............................................38098
    Appendix J amended.............................................38100
701.105  Revised...................................................21058
702.170-13  (d) amended............................................38097
705.002  Amended...................................................21058
706.101-70 (Subpart 706.1)  Removed.................................6158
709.402  Revised...................................................21058
715.504  (a) amended...............................................21058
715.506  Amended...................................................21058
715.613  Revised....................................................6158
715.613-70  Revised.................................................6158
715.613-71  Revised.................................................6159
719.270  (d) amended...............................................21058
719.271-2  (b) (4) and (8) amended.................................21058
719.271-6  (a) introductory text amended; (a)(3) revised...........21058
725.706  (a) amended................................................4144
728.305  (a)(2) list revised........................................4144
731.205-6  (b)(2) amended..........................................21058
731.371  (a) amended...............................................21058
732.402  Added.....................................................38097
732.406-70  Revised.................................................4145
732.406-70-1  Revised...............................................4145
732.406-70-2  Revised...............................................4145
732.406-70-3  Revised...............................................4145
732.406-70-4  Revised...............................................4145
732.406-70-5  Revised...............................................4145
733  Heading revised................................................4145
736.603  Amended...................................................21059
750.7110-2  Amended................................................38097
752.202  (d) amended................................................4145
    Redesignated as 752.202-1 and (d) amended......................38098
752.202-1  Redesignated from 752.202 and (d) amended...............38098
752.219-8  Amended.................................................21059
752.7026  Revised..................................................38098
Chapter 8
801  Nomenclature change...........................................28559
801.301  (c) added.................................................28559
801.404  Amended...................................................49016
801.602  Revised...................................................24010
801.602-70  (a)(4)(ii) removed; (a)(4) (iii) through (xi) 
        redesignated as (a)(4) (ii) through (x); (b) and (d) 
        revised; (i) added.........................................28559
    (a)(6) revised; (a)(7) and (g) amended.........................49016

[[Page 668]]

801.602-71  (b) (1), (2), and (3) amended; (a) and (b)(5) revised 
                                                                   28559
    (b) (2) and (4) amended........................................49017
801.602-72  (a) amended; (d) revised...............................28559
    (b) amended....................................................49017
801.603-1  Added...................................................24010
801.603-3  Removed.................................................24010
801.603-4  Removed.................................................24010
801.603-70  (c) removed............................................24010
801.670-1  Removed; new 801.670-1 redesignated from 801.670-6......24010
801.670-2  Removed; new 801.670-2 redesignated from 801.670-7......24010
801.670-3  Removed; new 801.670-3 redesignated from 801.670-12.....24010
801.670-4  Removed; new 801.670-4 redesignated from 801.670-13; 
        (a) removed and (b), (c), and (d) redesignated as (a), 
        (b), and (c)...............................................24010
801.670-5  Removed; new 801.670-5 redesignated from 801.670-14.....24010
801.670-6  Redesignated as 801.670-1; new 801.670-6 redesignated 
        from 801.670-15............................................24010
801.670-7  Redesignated as 801.670-2...............................24010
801.670-8  Removed.................................................24010
801.670-9  Removed.................................................24010
801.670-10  Removed................................................24010
801.670-11  Removed................................................24010
801.670-12  Redesignated as 801.670-3..............................24010
801.670-13  Redesignated as 801.670-4..............................24010
801.670-14  Redesignated as 801.670-5..............................24010
801.670-15  Redesignated as 801.670-6..............................24010
801.690  Added.....................................................24010
801.690-1  Added...................................................24010
801.690-2  Added...................................................24011
801.690-3  Added...................................................24011
801.690-4  Added...................................................24011
801.690-5  Added...................................................24012
801.690-6  Added...................................................24012
801.690-7  Added...................................................24012
801.690-8  Added...................................................24012
801.690-9  Heading added...........................................24012
802.100  Nomenclature change.......................................28559
    Revised........................................................24013
806.302-5  (a) and (b) amended.....................................28560
808.304-1  (b) introductory text amended...........................28560
808.307-2  Revised.................................................28560
810.001  Added.......................................................281
810.004  Added.......................................................281
810.004-70--810.004-72  Added........................................282
810.005  Removed.....................................................282
813.103  (a) amended...............................................28560
813.506-70  Revised................................................28560
814.201  (d)(1) table and (2) table revised........................49017
814.202-4  Amended.................................................49017
814.404-1  (b) amended.............................................28560
815  Nomenclature change....................................28559, 42439
815.805-5  (a) and (b) amended.....................................42439
815.7001  (c) introductory text amended; (c)(5) revised............49017
819  Nomenclature change...........................................37317
819.602-3 (Subpart 819.6)  Added...................................46083
819.806-2  Revised.................................................37317
819.806-3  Added...................................................37317
819.806-4  Revised.................................................37317
819.807-70  Heading revised; text amended..........................46083
819.7004  Amended..................................................37317
    Heading revised; text amended..................................46083
825.108  Revised...................................................32012
825.202-70  (c) amended............................................32012
825.203  Amended...................................................32012
833  Nomenclature change...........................................28559
833.103  (d) revised...............................................28560
    (b)(1) revised; (f)(2) amended.................................49017
833.104  (c) amended...............................................28560
833.106  Revised...................................................28561
    Corrected......................................................32013
833.211  (c) and (d) amended.......................................28561
836  Nomenclature change...........................................49017
836.202  Added.......................................................282
    (b) corrected...................................................1276
836.302--836.371 (Subpart 836.3)  Heading revised....................282
836.606-72  Revised..................................................282
842.705  (b) nomenclature change...................................49017
849  Nomenclature change...........................................42439
849.107  Amended...................................................42440
852.233-2  Footnote ** revised.....................................28561
852.233-70  Added..................................................28561
    Amended........................................................49017

[[Page 669]]

852.236-88  Introductory text, (a) clause and (b) clause amended 
                                                                   28561
    (a) and (b) corrected..........................................32013
    (b) amended....................................................49017
852.236-90  Added....................................................282
Chapter 9
Authority citations revised........................................38422
901.102  Revised...................................................38422
902.100  Redesignated as 902.101 and amended.......................38422
902.101  Redesignated from 902.100 and amended.....................38422
904.601-70  (b)(3)(ii) revised.....................................38422
904.601-71  Added..................................................28717
912.300--912.304 (Subpart 912.3)  Revised..........................38422
913.505-1 (Subpart 913.5)  Revised.................................38423
913.505-2  Removed.................................................38423
915.612  (a) revised...............................................38423
915.613  Revised...................................................38423
915.807  Added.....................................................38423
915.808  (a) added.................................................38424
917.504  Revised...................................................38424
917.505-70  Heading and (a) revised................................38424
917.505-71  (b) and (c) revised; (d) and (e) added.................38424
919.501  Revised...................................................38425
919.602-1 (Subpart 919.6)  Added...................................38425
919.705-2  Added...................................................38425
919.705-5  (a)(5) added............................................38425
952  Table of contents corrected...................................38425
952.204-2  Amended.................................................38425
952.209-72  Amended................................................38425
952.212-70  Revised................................................38425
952.212-71  Revised................................................38426
952.212-72  Added..................................................28717
952.219-9  Amended.................................................38426
970.0404-4  (a)(1) revised; (a)(2) removed.........................38426
970.0406  Added....................................................28717
970.1901  (i) added................................................38426
970.3101-6  (a) (3) revised; (a) (10), (11), and (12) added.........1607
970.3102-7  Revised.................................................1607
970.3102-17  (a) revised............................................1608
970.3102-19  Added..................................................1608
970.3102-20  Added..................................................1609
970.3102-21  Added..................................................1610
970.3103  Correctly designated......................................1610
970.5204-13  (e) (1), (8), (11), (12) and (27) revised; (e) (33) 
        and (34) added..............................................1610
    Amended........................................................38426
970.5204-14  (e) (1), (6), (9), (10), and (24) revised; (e) (31) 
        and (32) added..............................................1610
970.5204-22  Note A revised........................................38426
970.5204-33  Revised...............................................38426
971.103  (a) (3) and (4) added.....................................38427
Chapter 10
1033  Authority citation revised...................................17298
Chapter 12
Revised; interim...................................................44525
Chapter 13
1317.7001 (Subpart 1317.70)  Added..................................3807
1352.217-90--1352.217-112  Added....................................3808

                                  1988

48 CFR
                                                                   53 FR
                                                                    Page
Chapter 7
701.105  Revised....................................................4979
    Revised (OMB number)...........................................50630
701.601  Revised....................................................4980
701.602-3  Added....................................................6829
702.170-10  Revised.................................................4980
702.170-13  (c)(4) amended.........................................50630
728.302  Removed...................................................50630
728.305  Redesignated as 728.305-70 and heading revised............50630
728.305-70  Redesignated from 728.305 and heading revised..........50630
728.307-2  Revised.................................................50630
728.309  Added.....................................................50630
728.313  Added.....................................................50630
728.370  Removed...................................................50631
731.205-6  (a)(2) and (3)(i) revised...............................50631
731.371  (c)(1) revised............................................50631
731.772  (c)(1) revised............................................50631
733  Revised........................................................4980
733.7002  (d) amended..............................................13410
    (b) removed; (c) and (d) redesignated as (b) and (c) and 
amended............................................................50631
733.7003  (b) amended..............................................13410
    (d) amended....................................................50631
733.7004  (b) amended..............................................50631
733.7005  (a) and (b) amended......................................50631

[[Page 670]]

733.7007  (a) introductory text and (b) amended....................50631
733.7008  (a) and (b) amended......................................50631
736.603  Amended...................................................50631
742.770  Amended...................................................50631
750.7000 (Subpart 750.70)  Removed..................................6829
750.7107  (d) revised...............................................4982
752.228-3  Added...................................................50631
752.228-7  Added...................................................50632
752.228-9  Added...................................................50632
752.228-70  Removed................................................50631
752.7001  Amended..................................................50632
752.7003  Revised...................................................6829
752.7014  Revised..................................................50632
752.7028  Amended..................................................50632
752.7031  (b) and (c) amended......................................50632
753  Revised.......................................................50632
Chapter 7  Appendix B removed......................................50633
    Appendixes D and J amended.....................................50633
Chapter 8
807  Added.........................................................43210
810.004-70  (b) and (e) revised.....................................7755
836.202  (b) redesignated as (c); new (b) added; new (c) amended 
                                                                    7756
    (b) correctly revised...........................................9631
836.204  Added......................................................1631
836.602-2  (a) and (b) revised; nomenclature change; interim........1631
836.602-3  Nomenclature change; interim.............................1631
836.602-4  Nomenclature change......................................1631
836.602-5  Nomenclature change......................................1631
852.207-70  Added..................................................43211
    Correctly designated and corrected.............................46872
852.207-71  Added..................................................43212
    Correctly designated and (a) and (b) corrected.................46872
852.207-72  Added..................................................43212
    Correctly designated and corrected.............................46872
    Correctly designated...........................................48615
852.210-77  Introductory text amended...............................7756
852.236-72  Amended; interim........................................1631
    Correctly designated............................................2669
852.236-75  Amended; interim........................................1631
    Correctly designated............................................2669
852.236-81  Amended; interim........................................1632
852.236-82  Amended; interim........................................1632
852.236-83  Amended; interim........................................1632
852.236-84  Introductory text added; interim........................1632
852.236-88  (b)amended; interim.....................................1632
852.236-90  Amended.................................................7756
852.236-91  Added; interim..........................................1632
Chapter 9
927  Authority citation revised....................................51278
927.370  Added.....................................................51278
970  Authority citation revised....................................21648
970.0304 (Subpart 970.03)  Removed.................................24231
970.0407  Amended..................................................24231
970.0811  Removed..................................................24231
970.0870--970.0872  Removed........................................24231
970.0902  Removed..................................................24231
970.0905  (a) designation removed and amended; (b) removed.........24231
970.1508-1  (a) designation removed; (b) and (c) removed...........24231
970.1901  (a) through (g) removed; (h) and (i) redesignated as (a) 
        and (b)....................................................24231
970.2001 (Subpart 970.20)  Removed.................................24231
970.2202--970.2204  Removed........................................24231
970.2206  (a) removed; (b) designation removed.....................24231
970.2208  Amended..................................................24231
970.2210  (a) designation removed and amended; (b) removed.........24231
970.2213  Removed..................................................24231
970.2214  Removed..................................................24231
970.2501 (Subpart 970.25)  Removed.................................24231
970.2800  Removed..................................................24231
970.2801  Removed..................................................24231
970.2803--970.2805  Removed........................................24231
970.2903  (a) designation removed and amended; (b) removed.........24231
970.3101-4  (a) designation removed and amended; (b) removed.......24231
970.3102-7  Revised................................................21648
970.3102-15  Heading, (a), and (b) heading amended.................24231
970.3103  Existing text designated as (a); new (b) added...........21648
970.3600  Removed..................................................24231

[[Page 671]]

970.3601  Removed; new 970.3601 redesignated from 970.3606.........24231
970.3602--970.3605  Removed........................................24231
970.3606  Redesignated as 970.3601.................................24231
970.3607  Removed..................................................24231
970.3608  Removed..................................................24231
970.4401--970.4409 (Subpart 970.44)  Removed.......................24231
970.4601 (Subpart 970.46)  Removed.................................24231
970.4901  Heading amended; (a) designation removed; (b) removed....24231
970.5204-13  Heading revised; text amended.........................21648
970.5204-14  Amended...............................................21649
970.5204-17  Added.................................................21649
    Corrected......................................................24830
970.5204-22  Revised...............................................24231
970.7101--970.7110 (Subpart 970.71)  Added.........................24232
Chapter 10
1033.103 (Subpart 1033.1)  Added...................................12771
Chapter 12
1201.403  Amended..................................................28397
1201.602  Heading revised..........................................28397
1201.670  Removed..................................................28397
1202.170  (d) revised..............................................28398
1204.602  (c) amended..............................................28398
1204.804-5  Revised................................................28398
1205.303 (Subpart 1205.3)  Added...................................28398
1205.303  Corrected................................................34301
1205.402-70  Revised...............................................28398
1206.102  (b) amended..............................................28399
1206.302.1  Amended................................................28399
1206.304  (a)(1)(ii), (b), and (d) revised.........................28399
1207.305  (a) revised..............................................28399
1213.203-1  Revised................................................28399
1213.505-2  Amended................................................28399
1214.406-3  Amended................................................28399
1214.470  Amended..................................................28399
1214.501 (Subpart 1214.5)  Removed.................................28399
1215.612-70  Removed...............................................28399
1215.807-70  (e) revised...........................................28400
1215.905-70  (b)(5)(i) table and (ii) table amended................28400
1215.7000  Amended.................................................28400
1216.170  Removed..................................................28400
1216.7001--1216.7002 (Subpart 1216.70)  Removed....................28400
1217.7001  Amended.................................................28400
1219.201  Amended..................................................28400
1222.7002  (a) amended; (b) revised................................28400
1223.7001  (b) amended.............................................28400
1227.409  (a), (b), and (c) amended................................28400
1228.306-7001  Correctly designated................................28400
1229.7002  Revised.................................................28400
1229.7003  Removed.................................................28400
1232.7001 (Subpart 1232.70)  Removed...............................28400
1233.104  (c) amended..............................................28400
1236.603  Amended..................................................28400
1242.705-2  Revised................................................28400
1242.708  Amended..................................................28400
1243  Added........................................................28400
1245.101  Revised..................................................28401
1245.505-70  Revised...............................................28401
1246  Authority citation revised...................................30177
1246.701--1246.772 (Subpart 1246.7)  Revised.......................30177
1252.207-70  Revised...............................................28401
    Corrected......................................................31007
1252.215-72  Amended...............................................28402
    Corrected......................................................31007
1252.222-70  Amended...............................................28402
    Corrected......................................................31007
1252.222-75  Amended...............................................28402
    Corrected......................................................31007
1252.245-70  Amended...............................................28402
    Corrected......................................................31007
1253.215-70  (a) revised...........................................28402
1253.222-70  Heading revised.......................................28402
1253.227  Redesignated as 1253.227-70; new 1253.227 added..........28402
1253.227-70  Redesignated from 1253.227............................28402
1253.246-70  Heading revised.......................................28402

                                  1989

48 CFR
                                                                   54 FR
                                                                    Page
Chapter 7
701.105  (a) amended...............................................16122
702.170-13  (d) removed............................................37334
704.404  Redesignated from 704.405.................................16122
704.405  Redesignated as 704.404...................................16122
705.202  (b)(1) revised............................................28069
706.302-70  (b)(4) added...........................................28069
    (c)(3) added...................................................46389

[[Page 672]]

706.501  Amended...................................................46389
709.503 (Subpart 709.5)  Added.....................................16122
714.406-3  Amended.................................................46389
715.605-70  Revised................................................46389
715.613-70  (a) through (c) redesignated as (b) through (d); new 
        (a) added..................................................28069
715.613-71  (a) through (d) redesignated as (b) through (e); new 
        (a) added..................................................28069
716.303  Added.....................................................46390
725.270 (Subpart 725.2)  Removed...................................16122
728.305-70  (a) introductory text amended; (a)(2) revised..........16122
731.205-6  (a)(3)(i) revised.......................................46390
731.371  (a) and (c)(1) revised....................................46390
731.772  (c)(1) revised............................................46390
732.406-70-2  (c) amended..........................................46390
732.406-70-3  (a), (b) introductory text, (7), (c) introductory 
        text, (d), (e)(1) (ii) and (iii), and (2) introductory 
        text amended...............................................46391
732.406-70-5  Amended..............................................46391
733.7001--733.7008 (Subpart 733.70)  Revised.......................20597
734.003  Revised...................................................37334
736.602-2  Revised.................................................46391
752.225-9  Amended.................................................16122
752.228-3  Existing text designated as (a), (b) and (c); new (a) 
        and (b) revised............................................16122
752.228-7  Amended.................................................16122
752.232-70  Amended................................................46391
752.7004  Clause title and (g) revised.............................16123
752.7013  Revised..................................................46391
752.7018  Amended..................................................46391
752.7019  Revised..................................................46391
752.7026  (a) amended.......................................16123, 37334
    Revised........................................................46392
752.7031  (c) amended..............................................28069
    (c) and (d) removed; new (c) added.............................37335
    Revised........................................................46392
Chapter 8
Chapter 8  Heading revised.........................................24173
    Nomenclature changes...........................................40062
801  Part heading revised..........................................31961
801.000  Amended...................................................31961
801.102  Amended...................................................31961
801.103  (a) amended...............................................40062
801.104-1  Amended.................................................31961
    (a) amended....................................................40062
801.201  Amended...................................................31961
801.201-1  Amended.................................................31961
801.301--801.304 (Subpart 801.3)  Heading revised..................40062
801.301  (a) and (c) amended.......................................31962
801.301-70  (b)(2) amended.........................................31962
    (b)(2) amended.................................................40062
801.303  Amended...................................................31962
801.304  Amended...................................................31962
    Heading amended................................................40062
801.403  Revised...................................................31962
801.404  Amended...................................................31962
801.470  (b) amended...............................................31962
    (a) amended....................................................40062
801.602  (a) amended...............................................31962
801.602-2  (a) and (b) revised.....................................31962
801.602-3  Added...................................................31962
801.602-70  (a) introductory text, (1), (2), (3), (4) (vi) and 
        (vii), (b)(2), (d), and (h)(1) and (2)(i) revised; (j) 
        added......................................................31963
801.602-71  (b)(4) removed; (b) (5), (6), and (7) redesignated as 
        (b) (4), (5), and (6); (b) heading, (1), (3), new (5), new 
        (6), (c) (1) and (2) amended; (c) heading and (d) revised; 
        (e) added..................................................31963
    (b)(3) and (c) introductory text amended.......................40062
801.602-72  (d) introductory text revised; (e) added...............31964
    (d)(4), (5), and (6)(iv) amended...............................40062
801.603-70  (b) amended............................................40062
801.603-71  (b), (c), and (d) amended..............................31964
    (a), (d), and (e) amended......................................40062
801.603-72  Removed................................................31964
801.670  Amended...................................................31964
801.670-2  (a)(3) amended..........................................31964
    (b) amended....................................................40062
801.670-3  (a) amended.............................................31964
801.670-4  Heading, introductory text, (a) (1) and (2), and (b)(1) 
        revised....................................................31964
801.670-5  (a) introductory text, (2), (6), and (9), and (b) 
        amended....................................................31964
    (a)(2) amended.................................................40062
801.670-6  Amended..........................................31964, 40062
801.680  (d) amended...............................................31964
801.690-1  (h) and (j) revised.....................................31964
    (d) and (e) amended............................................40062
801.690-2  (a) amended.............................................31964

[[Page 673]]

801.690-3  (a), (c) introductory text, and (1), and (d) amended; 
        (b) revised................................................31964
    (d) amended....................................................40062
801.690-4  (c)(1)(i) and (3)(i)(A) and (f) revised; (c)(2)(i)(C) 
        and (3)(i)(D) undesignated paragraphs and (g) added........31964
801.690-5  (a) amended.............................................31965
801.690-6  Revised.................................................31965
801.690-7  (a) amended; (b) and (d) revised........................31965
801.690-8  Revised.................................................31965
802.100  (a) and (b) amended.......................................40062
803.101-3  Heading amended.........................................40062
803.104  Added.....................................................47086
803.104-5  Added...................................................47086
803.104-9  Added...................................................47087
803.104-11  Added..................................................47087
803.104-12  Added..................................................47087
805.207  (a) amended...............................................40063
806.302-5  (c) introductory text and (3)(ii) amended...............40063
806.304  (a)(1)(i) amended.........................................40063
806.401  Amended...................................................40063
806.501  (a) amended...............................................40063
807.302  (a) amended...............................................40063
807.304-72  (d) (i) and (ii) redesignated as (d) (1) and (2); (b), 
        new (d)(2) and (e) amended.................................40063
808.001  (a)(6) amended............................................40063
808.307-70  Amended................................................40063
808.404-1  (a) and (b) amended.....................................40063
808.405-5  Introductory text amended...............................40063
809.106-1  (b) and (c) amended.....................................30044
    (a) amended....................................................40063
809.206  Nomenclature change; (b) introductory text and (3) 
        amended....................................................30044
    (a) and (b) amended............................................40063
809.270  Nomenclature change.......................................30044
809.404  Nomenclature change.......................................30044
809.405  Nomenclature change.......................................30044
809.702  Amended...................................................40063
810.006  Nomenclature change; (c)(3) and (8) amended; (e)(1) 
        revised....................................................30044
    (c) (2), (9), and (11) amended.................................40063
810.007  Nomenclature change; (a) (1) and (2) amended..............30044
    (a)(1) amended.................................................40063
810.011  Amended...................................................40063
812.302  (c)(8) amended............................................40063
813.103  (a) and (b) amended.......................................40063
814.103-1  Amended.................................................40063
814.201  (b) revised; (c) and (f)(3) amended.......................30044
814.304-4  Amended.................................................40063
814.404-70  Amended................................................40063
814.406-3  Nomenclature change.....................................30044
814.406-4  Nomenclature change.....................................30044
814.407-1  Removed.................................................30044
    (a) amended....................................................40063
814.407-71  (a) and (b) amended....................................30044
    (a) amended....................................................40063
814.408  (a) and (b) amended.......................................30045
    (b) amended....................................................40063
815.502  Amended...................................................40063
815.506  Heading amended...........................................40063
    (a) amended....................................................42508
815.506-1  (a) amended.............................................40063
815.607 (Subpart 815.6)  Added.....................................42508
    Correctly revised..............................................45736
815.804-2  Removed.................................................42508
815.804-70  Amended................................................40063
815.805-5  (a) amended.............................................40063
    Removed........................................................42508
815.901 (Subpart 815.9)  Removed...................................42508
815.7001  (c)(4), (d)(1), (4), and (e) amended.....................40064
    (d)(2) removed; (d) (3) through (8), and (e) and (f) 
redesignated as (d) (2) through (7) and (f) and (g); (c) 
introductory text and (5), (d) introductory text and (1) revised; 
(e) added..........................................................42508
815.7002  (b) amended..............................................40064
816.102  (c) amended; (b) revised..................................30045
816.603  Amended...................................................40064
816.7001  Nomenclature change......................................30044
    (b)(1)(ii) amended.............................................40064
817.102-1  Revised...................................................980
817.202  Nomenclature change; (a) designation and (b) removed........980
817.402  Nomenclature change.........................................980
    Amended........................................................40064
819.000  Amended...................................................40064
819.201  (a) revised; (b) and (d) amended..........................40064
819.202-5  Amended.................................................40064
819.602-3  (a), (c), and (d) amended...............................40064

[[Page 674]]

819.801  (b) amended...............................................40064
819.807-70  Amended................................................40064
819.7002  (a) amended..............................................40064
819.7004  Amended..................................................40064
820.104  Amended...................................................40064
822.478  (a), (b), and (c) amended.................................40064
824.102  Amended...................................................40064
824.202  Amended...................................................40064
825.102-70  (b) amended............................................40064
825.202-70  (b) amended............................................40064
825.203  Amended...................................................40064
825.902  Amended...................................................40064
828.106-6  Added...................................................30045
828.203--828.203-2 (Subpart 828.2)  Removed........................24173
828.307-1  Added...................................................24173
828.7101  (a) and (b) amended......................................24173
    Nomenclature change............................................30044
829.202-70  (a)(2) amended.........................................24173
829.270  (a) amended...............................................24173
829.270-1  (a), (b), and (e) amended...............................24173
829.270-2  Heading revised.........................................24173
    Heading revised; (b) amended...................................40064
829.302 (Subpart 829.3)  Removed...................................24173
831.7001-1  (b) introductory text and (2) amended..................40064
831.7001-3  (a) (1) and (8) amended................................40064
831.7001-4  (b)(1) and (c) amended.................................40064
831.7001-6  (b)(5) amended.........................................40064
831.7001-7  Amended................................................40064
832.805-70  (b) amended............................................40065
833.102  Amended...................................................40065
833.103  Heading, (b)(7) introductory text and (i) amended.........40065
833.104  (a), (b), and (c) amended.................................40065
833.105  (a) amended...............................................40065
833.211  (d) amended...............................................40065
836.202  (c) amended...............................................40065
836.208  Amended...................................................40065
836.602-2  (a) amended.............................................40065
836.606-72  Amended................................................40065
837.200  Amended...................................................40065
837.204  (c) and (g) amended.......................................40065
837.205  (a)(3), (b), (c) (2) and (3) amended......................40065
837.270  (b) and (c) amended.......................................40065
837.271-1  (b) amended.............................................40065
837.7003  (e) amended..............................................40065
837.7004  (b) and (e) amended......................................40065
842.705  (b) amended...............................................40065
846.408-70  (a)(1) amended.........................................40065
846.470  (a) amended...............................................40065
847.304  Heading amended...........................................40065
847.304-1  Heading amended.........................................40065
849.107  Amended...................................................40065
852.203-70  (a) and (b) amended....................................40065
852.210-70  (c) amended............................................40065
852.210-73  Amended................................................40065
852.210-76  Amended................................................30045
852.216-70  (e) added..............................................30045
852.219-70  Amended................................................40065
852.233-2  Nomenclature change.....................................30044
    Amended........................................................40065
852.236-76  Amended................................................40066
852.236-82  Amended................................................40066
852.236-83  (a)(2)(ii) and (6)(iii) amended........................40066
852.236-89  (b), (c), and (d) amended..............................40066
853.000  Amended...................................................40066
853.107  Amended...................................................40066
870--871 (Subchapter I)  Heading amended...........................40066
870.111-5  (a) and (b) amended.....................................40066
870.112  Nomenclature change.......................................30044
    (b) amended.............................................30045, 40066
870.113  (b)(4) amended............................................40066
870.114-3  Introductory text amended...............................40066
870.114-4  Amended.................................................40066
871.101  Amended...................................................40066
871.201-3  Amended.................................................40066
871.206  Amended...................................................40066
Chapter 9
901.602-3  Added...................................................27645
901.603-71  Removed; new 901.603-71 redesignated from 901.603-72 
                                                                   27645
901.603-72  Redesignated as 901.603-71; new 901.603-72 
        redesignated from 901.603-73...............................27645
901.603-73  Redesignated as 901.603-72.............................27645
904.404  (d)(3) revised............................................27646
906.303-70  Revised................................................27646
908.7121  Revised..................................................27646
913.505-3  Added...................................................27646
916.301-3  (c) amended.............................................27647
916.405  (e) introductory text revised.............................48614
932.111  Removed....................................................9808

[[Page 675]]

932.908--932.970 (Subpart 932.9)  Added.............................9808
932.7100--937.7107-2 (Subpart 932.71)  Removed......................9808
935.014  Removed...................................................27647
942.1004  Revised..................................................27647
945.101  Revised...................................................27647
945.505-5  Revised.................................................27647
945.505-14  (b) revised; table amended.............................27647
945.607-2  Revised.................................................27648
945.608-6  Added...................................................27648
951.7000--951.7002 (Subpart 951.70)  Added.........................17736
952.232  Removed....................................................9809
952.232-1  Removed..................................................9809
952.232-2  Removed..................................................9809
952.232-3  Removed..................................................9809
952.232-4  Removed..................................................9809
952.232-5  Removed..................................................9809
952.232-6  Removed..................................................9809
952.232-7  Removed..................................................9809
952.232-8  Removed..................................................9809
952.232-10  Removed.................................................9809
952.232-70  Removed.................................................9809
952.232-71  Removed.................................................9809
952.232-72  Removed.................................................9809
952.232-73  Removed.................................................9809
952.251-70  Added..................................................17737
    Corrected......................................................26045
970.1509-8  (f) and (g) added......................................48614
970.3102-16  (c)(4) amended........................................27649
970.5204-13  (c), (d)(8) introductory text and (i) amended.........27649
970.5204-16  Amended...............................................48614
970.5204-22  Corrected..............................................1288
970.5204-27  (b) amended...........................................27649
970.5204-53  Added.................................................17738
970.5204-54  Added.................................................48614
970.7101  (c) corrected.............................................1288
970.7103  Introductory text and (c)(3)(vii) corrected...............1288
970.7104-30  Correctly designated...................................1288
Chapter 14
1428.306-70  (c)(1) revised........................................10989
1452.228-71  Revised...............................................10989

                                  1990

48 CFR
                                                                   55 FR
                                                                    Page
Chapter 7
701.105  (b) amended................................................6802
    Revised; eff. 10-31-90.........................................39976
701.372  (a) revised................................................6802
701.376-4  Amended..................................................6802
701.470  (a)(2) amended.............................................6802
701.601  (b)(4) amended.............................................6802
702.170-13  (b) amended.............................................6802
705.202  (c) added; interim.........................................8469
    Regulation at 55 FR 8469 confirmed; (c) republished............39154
705.207  Added; interim.............................................8469
    Revised........................................................39154
706.302-5  Added; interim...........................................8469
    Regulation at 55 FR 8469 confirmed; republished................39154
706.302-71  Added; interim..........................................8469
    Revised........................................................39154
706.501  Amended....................................................6802
715.613-70  (d)(2)(iv) and (4) amended..............................6802
715.613-71  (c)(1) introductory text, (d), (e) introductory text, 
        (1), and (3) amended; (f) correctly designated..............6802
719.272  Added; interim.............................................8470
    Regulation at 55 FR 8470 confirmed; republished................39154
726  Added; interim.................................................8470
    Revised........................................................39154
728.105-1  (b) amended..............................................6802
734  Revised; eff. 10-31-90........................................39976
735  Revised; eff. 10-31-90........................................39976
750.7109-1  Amended.................................................6802
750.7110-1  Amended.................................................6802
750.7110-2  Amended.................................................6802
750.7110-3  Amended.................................................6802
752.202-1  Amended..................................................6803
752.226-1  Added; interim...........................................8471
    Revised........................................................39156
752.226-2  Added; interim...........................................8471
    Revised........................................................39156
752.7002  Revised...................................................6803
752.7014  Revised...................................................6805
752.7020  Removed; eff. 10-31-90...................................39977
752.7032  Added.....................................................6805
Chapter 7  Appendixes G and H amended...............................6805
Chapter 8
801.602-70  (b)(1) revised.........................................31391
803.104  Suspended; eff. to 12-1-90................................25848
803.104-5  Suspended; eff. to 12-1-90..............................25848
803.104-9  Suspended; eff. to 12-1-90..............................25848

[[Page 676]]

803.104-11  Suspended; eff. to 12-1-90.............................25848
803.104-12  Suspended; eff. to 12-1-90.............................25848
819.201  (a) revised; (d) amended; interim.........................49899
819.202-5  (a) through (h) added; interim..........................49900
819.202-70  (a), (d), (m) and (n) revised; interim.................49900
819.7001--819.7004 (Subpart 819.70)  Heading amended; interim......49900
819.7001  (a) amended; (b) revised; interim........................49000
819.7002  Introductory text amended; (a) and (b) redesignated as 
        (b) and (c); new (a) added; new (c) revised; interim.......49900
819.7003  Revised; interim.........................................49901
819.7004  Heading revised; text amended; interim...................49901
852.219-70  (a) designation and (b) removed; undesignated text 
        amended; interim...........................................49901
871.101  Amended...................................................31600
871.102  (c) revised...............................................31600
Chapter 9
917.7301-1  (c)(1) revised.........................................33314
935.016  Added.....................................................33314
935.016-1  Added...................................................33314
935.016-2  Added...................................................33314
935.016-3  Added...................................................33315
935.016-4  Added...................................................33315
935.016-5  Added...................................................33316
935.016-6  Added...................................................33316
935.016-7  Added...................................................33316
935.016-8  Added...................................................33317
935.016-9  Added...................................................33318
970.3102-2  (i)(2)(i) amended.......................................5462
970.3102-15  Heading revised; (c) added............................41540
970.5204-4  Added...................................................5462
970.5204-13  Amended...............................................41540
970.5204-14  Amended...............................................41540
970.5204-16  Amended...............................................31053
970.5204-22  Amended...............................................41540
970.7104-4  Added..................................................41540

                                  1991

48 CFR
                                                                   56 FR
                                                                    Page
Chapter 7
701.105  (a) amended................................................2699
    (b) amended....................................................67224
701.372  (b) amended...............................................67224
701.376-4  Amended.................................................67224
701.470  (a)(2) amended............................................67224
701.601  (b)(3) amended............................................67224
702.170-3  (a) amended.............................................67224
702.170-10  (a)(1)(ii) amended.....................................67224
702.170-13  (a)(1), (2) and (b) amended............................67224
705.002  Amended....................................................2699
705.202  (c) revised; interim......................................27208
    Regulation at 56 FR 27208 confirmed............................52212
705.207  Revised; interim..........................................27208
    Regulation at 56 FR 27208 confirmed............................52212
706.302-5  Revised; interim........................................27208
    Regulation at 56 FR 27208 confirmed............................52212
706.302-71  Revised; interim.......................................27208
    Regulation at 56 FR 27208 confirmed............................52212
706.501  Amended...................................................67224
715.504  (a) revised................................................2699
    (a) amended....................................................67224
715.506  Revised....................................................2699
719.270  (k) amended...............................................67224
719.272  Revised; interim..........................................27208
    Regulation at 56 FR 27208 confirmed............................52212
726.000  Revised; interim..........................................27209
    Regulation at 56 FR 27209 confirmed............................52212
726.101  Revised; interim..........................................27209
    Regulation at 56 FR 27209 confirmed; (e) revised...............52212
726.102  Revised; interim..........................................27209
    Regulation at 56 FR 27209 confirmed............................52212
726.104  Amended; interim..........................................27209
    Regulation at 56 FR 27209 confirmed............................52212
726.201  Heading and (a) revised; interim..........................27209
    Regulation at 56 FR 27209 confirmed............................52212
726.301  (a) revised; interim......................................27209
    Regulation at 56 FR 27209 confirmed............................52212
    (a) amended....................................................52213
728.105-1  (b) amended.............................................67224
728.305-70  (a) revised............................................67224
753.107  Amended...................................................67226
7  Appendix H amended..............................................67226
731.205-6  (b)(2) amended...........................................7568

[[Page 677]]

731.371  (a)(1) amended.............................................7568
731.770  (a) amended...............................................67225
732  Revised.......................................................67225
737.206  (c)(2)(ii) amended........................................67225
737.270  (a) amended...............................................67225
750.7109-1  Amended................................................67225
750.7110-1  Amended................................................67225
750.7110-2  Amended................................................67225
750.7110-3  Amended................................................67225
752.219-8  Amended..................................................2699
752.226-1  Revised; interim........................................27209
    Regulation at 56 FR 27209 confirmed............................52212
752.226-2  Revised; interim........................................27210
    Regulation at 56 FR 27210 confirmed............................52212
752.228-3  (b) revised.............................................67226
752.232-70  (a), (b) and (d) amended...............................67226
752.7002  Amended...................................................2699
752.7004  (b)(4) amended...........................................67226
752.7006  Amended...................................................2699
752.7015  Amended...................................................2699
752.7018  Amended...................................................2699
752.7019  Amended...................................................2699
752.7026  Amended...................................................2699
    (b)(3) amended.................................................67226
752.7027  Revised...................................................7587
752.7029  Amended...................................................7587
752.7031  Amended...................................................2699
752.7033  Added.....................................................7588
753.107  Amended.............................................2699, 67226
Chapter 7  Appendix D revised.......................................7569
    Appendix G revised..............................................7586
    Appendixes C and D amended......................................7588
    Appendix H amended.............................................67226
Chapter 8
819.201  Regulation at 55 FR 49899 confirmed; (d) amended..........44011
819.202-5  Regulation at 55 FR 49900 confirmed; (c) introductory 
        text, (e), (f) and (g) amended; (c)(1), (2), (7) and (h) 
        revised....................................................44011
819.202-70  Regulation at 55 FR 49900 confirmed; (d) revised; (m) 
        amended....................................................44011
819.7001--819.7004 (Subpart 819.70)  Regulation at 55 FR 49900 
        confirmed..................................................44011
819.7001  Regulation at 55 FR 49900 confirmed......................44011
819.7002  Regulation at 55 FR 49900 confirmed......................44011
819.7003  Regulation at 55 FR 49901 confirmed......................44011
819.7004  Regulation at 55 FR 49901 confirmed......................44011
852.219-70  Regulation at 55 FR 49901 confirmed....................44011
Chapter 9
901.104-1  (a)(2) revised..........................................41964
901.105  Table revised (OMB numbers)...............................41964
901.603-70  Revised................................................41964
904.601  (c) amended...............................................41964
908.303--908.307 (Subpart 908.3)  Added............................41964
909.104-1  Removed.................................................41964
914.201-5  (a) revised..............................................8146
914.406-3  Amended.................................................41964
915.405-1  Amended.................................................41964
915.406-5  (a) revised..............................................8146
915.970-8  (b)(2)(i)(D) and (d)(1) introductory text amended.......41964
915.971-5  (d), (f) and (h) revised; interim........................5081
    (d), (f) and (h) revised.......................................28101
915.972  (a) introductory text revised; interim.....................5081
    (a) introductory text revised..................................28101
917.605  (b)(2)(iii) revised.......................................28102
919.805-2 (Subpart 919.8)  Added...................................42947
922.804-2  (c) amended.............................................41965
933.105  (a)(1)(i) revised.........................................41965
935.010  Revised...................................................41965
942.1401  Amended..................................................41965
942.1402  (a)(2) amended...........................................41965
942.1403-1  (a) and (c)(1) amended.................................41965
942.1403-2  (a) amended............................................41965
943.170  (i) amended...............................................41965
950.7000--950.7011 (Subpart 950.70)  Heading amended...............57827
950.7000  Amended..................................................57827
950.7001  Revised..................................................57827
950.7002  Amended..................................................57827
950.7003  Revised..................................................57828
950.7004  Removed..................................................57828
950.7005  Removed..................................................57828
950.7006  Revised..................................................57828
950.7007  Removed..................................................57828
950.7008  Removed..................................................57828
950.7009  Amended..................................................57828
950.7010  Revised..................................................57828

[[Page 678]]

950.7011  (c) revised; interim......................................5081
    (c) revised....................................................28102
    950.7011  Redesignated as 950.7101.............................57828
950.7101 (Subpart 950.71)  Heading added...........................57828
950.7101  Redesignated from 950.7011...............................57828
952.204-73  Amended................................................41965
952.212-73  Amended................................................41965
952.214-27  Removed................................................41965
952.215-18  Removed................................................41965
952.215-71  Removed.................................................8146
952.215-72  Removed.................................................8146
952.219-9  Amended.................................................41965
952.227-79  Amended................................................41965
952.235-70  Amended................................................41965
952.250-70  Revised................................................57828
952.250-71  Removed................................................57830
952.250-72  Removed................................................57830
970.0803  Revised..................................................41965
970.0901  Added....................................................65448
970.1509-5  (b) revised; interim....................................5081
    (b) revised....................................................28102
970.1509-8  (b), (c) and (d) revised; interim.......................5082
    (b) through (e) revised........................................28102
    (d) table corrected............................................38174
970.2870  Revised..................................................57830
970.3102-2  (d) amended............................................41965
970.3102-21  Revised; interim.......................................5083
    Revised........................................................28104
970.3102-22  Added; interim.........................................5084
    Added; final...................................................28104
970.5203-3  Amended................................................41965
970.5204-7  Removed................................................57830
970.5204-8  Heading amended........................................57830
970.5204-10  (b) amended...........................................41965
970.5204-12  Amended...............................................41965
970.5204-13  Amended; interim.......................................5084
970.5204-14  Amended; interim.......................................5085
    Amended........................................................28105
970.5204-15  Amended...............................................41966
970.5204-16  Amended; interim.......................................5085
    Amended........................................................28106
970.5204-18  Added; interim.........................................5085
    Added; final...................................................28106
970.5204-20  Added.................................................65448
    Amended.................................................28104, 41966
970.5204-21  Amended; interim.......................................5085
    Amended........................................................28106
970.5204-26  Amended...............................................41966
970.5204-31  Revised; interim.......................................5086
    Revised........................................................28106
    Amended........................................................41966
970.5204-32  Revised; interim.......................................5087
    Revised........................................................28107
970.5204-54  Revised...............................................28108
970.5204-55  Added; interim.........................................5087
    Added; final...................................................28108
970.5204-56  Added; interim.........................................5088
    Added; final...................................................28110
970.7104-3  Revised................................................41966
970.7104-12  (a) amended...........................................41966
970.7104-39  Amended...............................................41966
971.101  Revised...................................................41966
971.103  (a)(1)(ii) removed; (a)(1)(iii) and (iv) redesignated as 
        (a)(1)(ii) and (iii); new (a)(1)(ii) and (c)(2) revised....41966
Chapter 14
1401.301  Revised..................................................15838
1401.301-70  Added.................................................15838
1401.302  Revised..................................................15838
1401.303  Revised..................................................15838
1401.304  Revised..................................................15838

                                  1992

48 CFR
                                                                   57 FR
                                                                    Page
Chapter 7
701.105  (a) revised (OMB numbers)..................................5235
705.202  (b) revised................................................5235
706.302-70  (b)(2) amended..........................................5235
710  Added.........................................................23321
731.205-6  Revised..................................................5235
731.205-46  Revised.................................................5236
731.205-70  Added...................................................5236
731.371  Revised....................................................5236
731.372  Added......................................................5236
731.373  Added......................................................5236
731.772  Revised....................................................5236
731.774  Added......................................................5236
749.111-71  (a)(1), (2)(i) and (ii) amended.........................5236
752.200  Amended....................................................5236
752.210-70  Added..................................................23321
752.7000  Amended...................................................5237
752.7005  Removed..................................................23321
752.7015  Amended...................................................5237
752.7034  Added.....................................................5237
752.7035  Added.....................................................5237
Chapter 8
803  Authority citation revised....................................58718
803.104  Removed...................................................58718
803.7000--803.7002 (Subpart 803.70)  Added.........................58718

[[Page 679]]

817  Authority citation revised....................................44129
817.102-1  (a) amended.............................................44129
817.202  Amended...................................................44129
852  Authority citation revised....................................58718
852.203-71  Added..................................................58718
Chapter 9
909.104-1  (h) added; interim......................................32675
    Regulation at 57 FR 32675 confirmed............................48471
913.507  Added; interim............................................57639
922.7100--922.7101 (Subpart 922.71)  Added; interim................57639
923.570--923.570-3 (Subpart 923.5)  Added; interim.................32676
    Regulation at 57 FR 32676 confirmed............................48471
923.570-1  (a) introductory text and (2)(iii) corrected............41974
952.222-70  Added; interim.........................................57639
970.2274--970.2274-2  Added; interim...............................57639
970.2305  Added; interim...........................................32676
    Regulation at 57 FR 32676 confirmed............................48471
970.2305-1  Added; interim.........................................32676
    Regulation at 57 FR 32676 confirmed............................48471
970.2305-2  Added; interim.........................................32676
    Regulation at 57 FR 32676 confirmed............................48471
970.2305-3  Added; interim.........................................32676
    Regulation at 57 FR 32676 confirmed............................48471
970.2305-4  Added; interim.........................................32676
    Regulation at 57 FR 32676 confirmed............................48471
970.2305-5  Added; interim.........................................32677
    Regulation at 57 FR 32677 confirmed............................48471
970.5204-57  Added; interim........................................32677
    Regulation at 57 FR 32677 confirmed............................48471
970.5204-58  Added; interim........................................32677
    Regulation at 57 FR 32677 confirmed............................48471
970.5204-59  Added; interim........................................57640

                                  1993

48 CFR
                                                                   58 FR
                                                                    Page
Chapter 7
701.105  (a) amended (OMB numbers)..................................8702
701.601  (b)(4) amended.............................................8702
701.704--701.707 (Subpart 701.7)  Added.............................8702
706.302-5  Revised..................................................8702
706.302-71  (a)(1) revised..........................................8702
709.507-2  Added...................................................42255
716.306  Added......................................................8702
719.272  Revised....................................................8702
726.000  Revised....................................................8702
726.104  Revised....................................................8702
726.301  Heading revised...........................................42255
726.302  Added.....................................................42255
733.7006  (d) removed; (e) through (h) redesignated as (d) through 
        (g).........................................................8703
737.206  (c)(3) amended; (c)(4) added..............................42255
737.270  Revised...................................................42255
752.209-71  Added..................................................42255
752.226-3  Added...................................................42255
752.7009  Amended...................................................8703
752.7029  Amended..................................................58596
752.7033  Amended; (b)(1) revised..................................58596
Chapter 7  Appendix D revised......................................58596
    Appendix J revised.............................................58611
Chapter 8
801  Authority citation revised....................................31914
801.602-70  (a)(4)(viii) amended...................................31914
814  Authority citation revised....................................48974
814.203-1  (a) designation and (b) removed.........................48974
833  Authority citation revised....................................48974
833.102--833.106 (Subpart 833.1)  Nomenclature change..............48974
833.106  Revised...................................................48974
836  Authority citation revised....................................48974
836.302  Removed...................................................48974
836.513 (Subpart 836.5)  Added.....................................48974
    Corrected......................................................58730
852  Technical correction..........................................58730
852.208-70  Removed................................................48974
852.214-73  Revised................................................48974

[[Page 680]]

852.233-2  Removed.................................................48974
852.236-87  Revised................................................48974
Chapter 9
904.601  (c) amended...............................................36364
904.601-70  (b) introductory text, (2) and (3)(ii) amended.........36364
904.7100--904.7103 (Subpart 904.71)  Added; interim................59684
905.403  Amended...................................................32307
905.403-70  Introductory text amended..............................32307
906.303-1(a)  amended..............................................36365
913.505-1  Heading and (a)(2) revised..............................36365
913.507  Corrected.................................................39679
915.504  (b)(6)(i) amended.........................................32307
915.971-4  (f) amended.............................................36365
915.971-6  (b) introductory text amended...........................36365
916.206  Removed...................................................36365
916.206-3  Removed.................................................36365
919.708  (b) removed...............................................36365
922.103-5  Added...................................................36151
922.473  (b) amended...............................................36365
922.803  (d) amended...............................................36365
922.804-2  (b)(3) amended..........................................36365
922.7001  (c)(3), (e), (f)(1) and (h) amended......................36365
922.7101  Corrected................................................39679
925  Authority citation revised.....................................8910
925.702 (Subpart 925.7)  Added; interim............................59684
925.7000--925.7004 (Subpart 925.70)  Added; interim.................8910
    Regulation at 58 FR 8910 confirmed.............................42688
933.170  (a) amended...............................................32307
935.016-4  (d) removed; (e), (f) and (g) redesignated as (d), (e) 
        and (f); new (f) revised...................................37870
935.016-5  Introductory text, (a), (b) introductory text and (c) 
        introductory text amended; (a)(3), (b)(5) and (c)(1) 
        revised; (b)(6) added......................................37870
935.016-6  (a) amended; (c) revised................................37870
935.016-7  (a)(1), (2) and (4) revised; (d) concluding text, (f), 
        (i)(2) and (j) amended; (i)(3) removed.....................37870
935.016-8  (c)(4) revised, (c) concluding text removed.............37870
937.7010--937.7040 (Subpart 937.70)  Added.........................36151
942.1004  Amended..................................................32307
952  Authority citation revised.....................................8910
952.204-73  Amended; interim.......................................59684
952.219  Removed...................................................36365
952.219-9  Removed.................................................36365
952.222-70  Corrected..............................................39679
952.225-70  Added; interim..........................................8911
    Corrected......................................................39679
    Regulation at 58 FR 8911 confirmed.............................42688
952.237-70  Added..................................................36152
    Corrected......................................................43287
952.250-70  Introductory text amended..............................32307
970.0404-4  (d) added; interim.....................................59684
970.1509-7  (a) and (c) amended....................................32308
970.1901  (a) amended..............................................36365
970.2201  (b)(5)(ii) revised.......................................36152
970.2270  (b)(2) introductory text amended.........................36365
970.2271  (b)(1), (2)(iv) and (3) amended..........................36365
970.2274-2  Corrected..............................................39679
970.3100--970.3103 (Subpart 970.31)  Heading amended...............32308
970.3102-2  (l)(2) amended.........................................36365
970.3102-20  Revised...............................................61628
970.3103  (c) added................................................61628
970.5204-13  (e)(33) revised.......................................61628
970.5204-14  (e)(31) revised.......................................61628
970.5204-15  (b)(2) and (c) amended................................32308
970.5204-20  Amended...............................................36365
970.5204-55  (c) amended...........................................32308
970.5204-59  Corrected.............................................39679
970.5204-60  Added.................................................34925
    Corrected......................................................43287
970.5204-63  Added.................................................36152
    Corrected......................................................43287
970.5204-61  Added.................................................61628
970.7103  (c)(3) amended...........................................32308
970.7104-11  Heading revised.......................................36365
970.7104-12  (f) amended...........................................32308
    (g) removed....................................................36365
970.7104-39  Amended...............................................32308
970.7201 (Subpart 970.72)  Added...................................34926

[[Page 681]]

                                  1994

48 CFR
                                                                   59 FR
                                                                    Page
Chapter 7
701.105  Revised; OMB numbers......................................33445
701.376-4  Amended.................................................33445
701.470  (a)(2) amended............................................33445
701.601  (b)(4) amended............................................33445
702.170-13  (a) and (b) revised....................................33445
703.403  Amended...................................................33446
706.501  Revised...................................................33446
710.070  (b) amended...............................................33446
715.504  (a) revised...............................................33446
725.705  Revised...................................................33446
728.105-1  (b) amended.............................................33446
728.307-70  Added..................................................33446
737.270  Amended...................................................33446
749.111-71  (b) amended............................................33446
750.7109-1  Amended................................................33446
750.7110-1  Amended................................................33446
750.7110-2  Amended................................................33446
750.7110-3  Amended................................................33446
752.225-9  Amended.................................................33447
752.228-70  Added..................................................33447
752.232-70  Introductory text amended..............................33447
752.7004  Amended..................................................33447
752.7017  Revised..................................................33447
752.7026  Amended..................................................33447
753.1  Amended.....................................................33447
Chapter 7  Appendix H amended......................................33447
Chapter 9
901.103-70  (a) amended.............................................9103
901.104-1  (a)(2) amended...........................................9103
901.170  Added......................................................9103
901.201-1  (b) and (d) amended......................................9103
901.301  (b) introductory text amended..............................9103
901.570  (b) amended................................................9103
901.601  Amended....................................................9103
901.602-3  (b)(3), (c)(7)(ii) and (iv) amended......................9103
901.603-1  Amended..................................................9103
901.603-71  (a) amended.............................................9103
901.603-72  (a) amended.............................................9103
902.101  Amended..............................................9103, 9104
903.104-11  Added..................................................11198
903.203  (a) amended................................................9104
903.303  (a) amended................................................9104
903.603  (a) amended................................................9104
904.401  Amended....................................................9104
904.403  (a) and (c) amended........................................9104
904.404  (d)(3) amended............................................24358
904.601  (c) amended................................................9104
904.601-70  (b) introductory text amended; (b)(4) removed...........9104
904.601-71  (a) and (b) amended.....................................9104
    (b) amended....................................................24358
904.702  (b) amended................................................9104
904.805  Amended....................................................9104
904.7000  Amended...................................................9104
904.7001  Amended...................................................9104
904.7002  Amended...................................................9104
904.7003  (c) amended...............................................9104
904.7004  Amended...................................................9104
904.7100--904.7103 (Subpart 904.71)  Regulation at 58 FR 59684 
        confirmed...................................................6221
905.403  (a) amended................................................9104
905.403-70  Introductory text amended...............................9104
    (c) removed....................................................24358
905.404-1  Amended..................................................9104
906.303-1  (a) amended..............................................9104
907.102  Amended....................................................9104
907.401  (f) amended................................................9104
907.402-70  (b) introductory text, (3), (c)(1)(iv) and (4) amended
                                                                    9104
908.307  (b) amended................................................9104
908.802  (b) amended................................................9104
908.1170  (a) and (b) amended.......................................9104
908.7101-2  (c) amended.............................................9104
908.7101-3  Amended.................................................9104
908.7101-4  (b) amended.............................................9104
908.7101-5  Amended.................................................9104
908.7101-6  (a) amended.............................................9104
908.7101-7  (b) amended.............................................9104
908.7107  (i) amended...............................................9105
908.7108  (b) amended...............................................9105
908.7112  Amended...................................................9105
908.7115  (a) amended...............................................9105
908.7116  (b) amended...............................................9105
908.7121  (b) amended...............................................9105
909.500  Amended...................................................66264
909.570-3  Amended.................................................66264
909.570-4  (a) amended; (b)(4) and (7) revised.....................66264
909.570-5  Revised.................................................66264
909.570-6  Revised.................................................66265
909.570-7  Revised.................................................66265
909.570-8  Revised.................................................66265
909.570-9  (a) introductory text revised; (a)(3) amended...........66265
909.570-10  Revised................................................66266
909.570-12  Revised................................................66266
909.570-14  (b)(4), (5), (7), (8) and (12) revised; (b)(6), (9) 
        and (11) amended...........................................66266

[[Page 682]]

909.570-15  (a) amended............................................66266
912.300  Amended....................................................9105
912.302  (e) amended................................................9105
912.304  (c) amended................................................9105
913  Heading amended................................................9105
913.505-1  (b)(2) amended...........................................9105
913.505-3  (d)(1) amended...........................................9105
914.201-5  (a)(1) amended...........................................9105
    (b) removed....................................................24358
914.406-3  (e) amended..............................................9105
914.407-8  Removed..................................................9105
914.407-70  Removed.................................................9105
914.408-2  Amended..................................................9105
915.406-5  (a)(1) and (2)(iv) amended...............................9105
    (d) removed....................................................24358
915.502  (a)(iv) and (b) amended....................................9105
915.504  (b)(6)(ii), (iv) and (vi) amended..........................9105
915.506  (b) amended................................................9105
915.506-2  (a) and (e) amended......................................9105
915.801  Amended....................................................9105
915.804-3  (b)(2)(iii), (c)(8), (g) and (i) amended.................9105
915.804-6  (e) and (i) amended......................................9105
915.805-5  (c)(1) amended...........................................9105
915.807  (d)(5)(h) amended..........................................9105
915.903  (f) amended................................................9105
915.970-4  (c) amended..............................................9105
915.970-8  (b)(1) and (h)(1) amended; (b)(2)(iv)(C) redesignated 
        as (c)......................................................9105
915.971-4  (h) amended..............................................9105
915.1003  (a) amended...............................................9105
916.203-4  (d)(2) amended...........................................9105
916.207-3  (d) amended..............................................9105
916.306  (c)(2) amended.............................................9105
916.404-2  (d) amended..............................................9105
916.405  (e) amended................................................9105
917.502--917.505-1 (Subpart 917.5)  Removed........................64790
917.504  (b)(9)(i) amended..........................................9105
917.7003  (b)(3) and (e) amended....................................9105
917.7006  Amended...................................................9105
917.7100-917.713  (Subpart 917.71) Removed.........................24358
917.7200  (b) amended...............................................9105
917.7300  (b) amended...............................................9105
917.7301-4  (a)(9) amended..........................................9105
917.7303  (b) amended...............................................9105
917.7401  Amended...................................................9105
917.7402  (c)(3) amended............................................9105
917.7403  (b) amended...............................................9105
917.7502  (b) amended...............................................9106
919.201  (c) amended................................................9106
919.501  (c) amended................................................9106
919.705-2  (a) amended.............................................24359
919.705-6  Amended..................................................9106
919.708  (c) amended................................................9106
920.102  Amended....................................................9106
920.106  Revised....................................................9106
922.103-4  (d)(1) amended...........................................9106
922.470  (a) amended................................................9106
922.471  (e) and (g)(2)(iii) amended................................9106
922.473  (a) and (b) amended........................................9106
922.608-5  Amended..................................................9106
922.800  Amended....................................................9106
922.804-2  (a)(1) amended...........................................9106
923  Heading revised................................................9106
923.7001  (a) amended...............................................9106
923.7002  (b) introductory text and (d) amended.....................9106
924.103  (b)(2) amended.............................................9106
924.202  (b) amended................................................9106
925.108  (b) amended................................................9106
925.204  (d) designation removed....................................9106
925.702 (Subpart 925.7)  Regulation at 58 FR 59684 confirmed........6221
925.901 (Subpart 925.9)  Revised....................................9106
928.202-70  Amended.................................................9106
932.501-2  (a)(3) amended...........................................9106
932.803  (d) amended................................................9106
932.970  (a)(1), (2), (b) heading, (1) and (2) amended..............9106
932.7003  (a) amended...............................................9106
932.7004-2  (d) amended.............................................9106
932.7004-3  (b) amended.............................................9106
933.103  (a), (d)(5) and (e) amended................................9106
933.104  (a)(3), (4)(iii), concluding text, (5)(i), (6), (b) and 
        (c)(2) amended..............................................9106
933.105  (a)(1)(ii), (g) and (h) amended............................9107
933.170  (b) through (e) amended....................................9107
935.016-3  Amended..................................................9107
935.016-4  (b)(5), (c) and (d) amended..............................9107
935.016-5  (b)(1)(ii) amended.......................................9107
935.016-6  (a) amended..............................................9107
935.016-7  (d)(4) amended...........................................9107
935.016-8  (a)(5), (e)(1), (10) and (11) amended....................9107
935.016-9  Introductory text amended................................9107

[[Page 683]]

935.070  Amended....................................................9107
936.70  Removed....................................................24359
936.73  Removed....................................................24359
936.202  (a) amended................................................9107
936.601  Amended....................................................9107
936.602-3  (c)(5) amended...........................................9107
936.602-4  (b) amended..............................................9107
936.603  Amended....................................................9107
936.605  (c)(1) and (3) amended.....................................9107
936.606  (f) amended................................................9107
936.702 (Subpart 936.7)  Heading revised............................9107
936.7002-3  (a) amended.............................................9107
936.7003-1  Amended.................................................9107
937.205 (Subpart 937.2)  Heading revised; redesignated as 937.207 
                                                                    9107
937.207 (Subpart 937.2)  Redesignated from 937.205; heading 
        revised; (b) designation and (7) removed....................9107
942.003  (b) amended................................................9107
942.101  (b) amended................................................9107
942.705-1  (a)(3) amended...........................................9107
942.705-3  Amended..................................................9107
942.705-4  Amended..................................................9107
942.705-5  Amended..................................................9107
942.708  Undesignated text designated as (b)........................9107
942.803  (c)(3)(vii) amended........................................9107
942.1401  Amended...................................................9107
942.1402  (a)(2) amended............................................9107
942.1403-1  (a) and (c)(1) amended..................................9107
942.1403-2  (a) amended.............................................9107
943.170  (g) introductory text, (1) and (3) amended.................9107
943.301  (c) amended...............................................24359
944.302  (a) and (c) amended........................................9107
944.305-1  (a) amended..............................................9107
944.307  (b) amended................................................9107
945.102-70  Introductory text and (c) amended.......................9107
945.104-70  (a)(5), (6), (7) and (11) amended.......................9108
945.303-1  Introductory text amended................................9108
945.304  (c) and (d) amended........................................9108
945.505-14  Table amended...........................................9108
945.570-2  (a), (b)(1), (2) and (g) introductory text amended.......9108
945.607-2  (b) amended..............................................9108
945.608-2  (b)(1)(ii) amended.......................................9108
945.608-6  (a) and (b) amended......................................9108
949.111  (a) and (c) amended........................................9108
949.501  (a) designation removed; amended...........................9108
950.104  Amended....................................................9108
950.7003  (b) amended...............................................9108
950.7006  (a) amended...............................................9108
950.7101  (a), (c)(2), (d), (e) and (g) amended.....................9108
951.102  (a) and (c)(1) amended.....................................9108
952.102-1 (Subpart 952.1)  Heading and (a) amended..................9108
    Removed........................................................24359
952.202-1  Amended..................................................9108
952.204-2  Amended..................................................9108
952.204-70  Introductory text amended...............................9108
952.204-71  Amended.................................................9108
952.204-72  Introductory text amended...............................9108
952.204-73  Regulation at 58 FR 59684 confirmed.....................6221
    Amended.........................................................9108
952.208-7  Introductory text amended................................9108
952.208-70  Introductory text amended...............................9108
952.209-70  Amended.................................................9108
    Revised........................................................66266
952.209-71  Amended.................................................9108
    Removed........................................................66267
952.209-72  Heading revised; amended...............................66267
952.212-70  Introductory text amended...............................9109
952.212-71  Introductory text amended...............................9109
952.212-72  Amended..........................................9109, 24359
952.212-73  Introductory text amended...............................9109
952.215-22  Amended.................................................9109
952.215-70  Amended.................................................9109
    Removed........................................................24359
952.216-15  Amended.................................................9109
952.223-71  Amended.................................................9109
952.223-72  Amended.................................................9109
952.223-75  Introductory text amended...............................9109
952.224-70  Amended.................................................9109
952.227-71  Amended.................................................9109
952.227-75  Amended.................................................9109
952.227-76  Amended.................................................9109
952.227-77  Amended.................................................9109
952.227-78  Amended.................................................9109
952.227-79  Introductory text amended...............................9109

[[Page 684]]

952.227-80  Introductory text amended...............................9109
952.227-82  Amended.................................................9109
952.233-2  Amended..................................................9109
952.235-70  Amended.................................................9109
952.236-70  Amended.................................................9109
952.236-71  Amended.................................................9109
952.236-72  Introductory text amended...............................9109
952.249-70  Amended.................................................9109
952.251-70  Amended.................................................9109
970.0000  Amended...................................................9109
970.0001  (b) introductory text amended.............................9109
970.0404-1  Amended.................................................9109
970.0404-2  (b), (d)(2)(i) and (ii) amended.........................9109
970.0404-3  (a) and (b) amended.....................................9109
970.0404-4  Regulation at 58 FR 59684 confirmed.....................6221
    (a)(3) removed.................................................24359
970.0406  Amended...................................................9109
970.0803  (b) amended...............................................9109
970.0905  Amended...................................................9109
970.1001  Amended...................................................9109
970.1509-1  (b) amended.............................................9109
970.1509-2  Heading amended.........................................9109
970.1509-4  (b)(6) amended..........................................9109
970.1509-6  (b)(1)(iii) and (e) amended.............................9109
970.1509-8  (d) table, (e) and (g) amended..........................9109
970.2201  (a) and (b)(3) amended....................................9109
970.2271  (b)(1), (2) and (3) amended...............................9110
970.2272  (b)(2) amended............................................9110
    (a) amended....................................................24359
970.2273  (a)(7), (8), (b) introductory text, (3), (c)(1)(iv), (2) 
        and (d) amended.............................................9110
970.2303-2  (e) added...............................................5531
    (d) amended.....................................................9110
970.2901  (b) amended...............................................9110
970.2902  Introductory text amended.................................9110
970.3001-2  Amended.................................................9110
970.3101-1  (c) amended.............................................9110
970.3101-2  (b)(1) amended..........................................9110
970.3102-1  (b) and (c) amended.....................................9110
970.3102-2  (h)(2)(ii), (l)(2)(iv), (6)(iv), (7) heading, (i)(A) 
        and (ii) amended............................................9110
970.3102-5  (a) amended.............................................9110
970.3102-9  Amended.................................................9110
970.3102-17  (a)(1) and (b) introductory text heading amended.......9110
970.3102-18  Amended................................................9110
970.3102-19  (d) introductory text, (5) concluding text, (e)(1) 
        and (2)(iii) amended........................................9110
970.3102-20  (d) amended............................................9110
970.3102-21  (b)(3) introductory text and concluding text amended 
                                                                    9110
970.3102-22  Amended................................................9110
970.3201  Amended...................................................9110
970.3271  Amended...................................................9110
970.5101  (c) amended...............................................9110
970.5203-1  Amended.................................................9110
970.5203-2  Amended.................................................9110
970.5203-3  Amended.................................................9110
970.5204-1  Amended.................................................9110
970.5204-2  Introductory text added.................................9110
970.5204-4  Amended.................................................9110
970.5204-5  Revised.................................................9110
970.5204-6  Revised.................................................9110
970.5204-8  Amended.................................................9110
970.5204-9  Amended; introductory text added........................9110
970.5204-11  Introductory text added................................9110
970.5204-12  Introductory text added................................9110
    Amended........................................................24359
970.5204-13  Amended; introductory text added.......................9110
970.5204-14  Amended; introductory text added.......................9110
970.5204-15  Amended; introductory text added.......................9111
970.5204-16  Introductory text added................................9111
970.5204-17  Amended; introductory text added.......................9111
970.5204-18  Amended; introductory text added.......................9111
970.5204-19  Introductory text added................................9111
970.5204-21  Amended; introductory text added.......................9111
970.5204-22  Introductory text added................................9111
970.5204-23  Introductory text added................................9111
970.5204-24  Amended; introductory text added.......................9111

[[Page 685]]

970.5204-25  Introductory text added................................9111
970.5204-26  Introductory text amended..............................9111
970.5204-28  Introductory text added................................9111
970.5204-29  Introductory text added................................9111
970.5204-30  Revised................................................9111
970.5204-31  Amended; introductory text added.......................9111
970.5204-32  Amended................................................9111
970.5204-33  (a) and (b) amended....................................9111
970.5204-34  Amended................................................9111
    Removed........................................................24359
970.5204-35  Heading amended; introductory text added...............9111
    Amended........................................................24359
970.5204-36  Heading amended; introductory text added...............9111
    Heading revised; amended.......................................66267
970.5204-37  Amended................................................9111
970.5204-38  Amended................................................9111
970.5204-41  Amended................................................9111
970.5204-42  Introductory text added................................9111
970.5204-43  Amended; introductory text added.......................9112
970.5204-45  Amended; introductory text revised; amended............9112
970.5204-50  Revised................................................9112
970.5204-52  Revised................................................9112
970.5204-54  Amended; introductory text added.......................9112
970.5204-55  Amended; introductory text added.......................9112
970.5204-56  Amended; introductory text added.......................9112
970.5204-57  Amended................................................9112
970.5204-58  Introductory text amended..............................9112
970.5204-60  Amended................................................9112
970.5204-61  Amended; introductory text added.......................9112
970.5204-62  Added..................................................5531
970.7102  Amended...................................................9112
970.7104-7  Table amended...........................................9112
970.7104-9  (b) amended.............................................9112
970.7104-12  (a) amended............................................9112
970.7104-19  (b) amended............................................9112
970.7104-22  (a) amended............................................9112
970.7104-24  Amended................................................9112
970.7104-25  Amended................................................9112
970.7104-27  (a)(2) amended.........................................9112
970.7104-28  (c) and (d) amended....................................9112
970.7107  (e), (f) and (g) amended..................................9112
970.7108  (a), (c) and (h) amended..................................9112
971.101  Amended....................................................9113
971.102  Amended....................................................9113
971.103  (a) introductory text and (b) amended......................9113
971.202  Amended....................................................9113
Chapter 12
Chapter  12 Revised................................................40270

                                  1995

48 CFR
                                                                   60 FR
                                                                    Page
Chapter 7
701  Technical correction..........................................12825
701.601  (b)(4) amended............................................11912
703  Technical correction..........................................12825
703.104-5 (Subpart 703.1)  Added...................................11912
703.403  Amended...................................................11912
715  Technical correction..........................................12825
715.413-2 (Subpart 715.4)  Added...................................11912
731  Technical correction..........................................12825
731.205-6  (d) amended.............................................11913
731.371  (b) amended...............................................11913
752  Technical correction..........................................12825
752.7004  (b)(5) amended...........................................11913
752.7035  Amended..................................................11913
Chapter  7 appendix G revised......................................11913
    appendix G corrected...........................................13212
Chapter 9
901.103  Amended; eff. 10-12-95....................................47307
901.103-70  Removed; eff. 10-12-95.................................47307
901.104-3  (a) amended; (a) designation and (b) removed; eff. 10-
        12-95......................................................47307
901.170  Removed; eff. 10-12-95....................................47307
901.301-71  Removed; eff. 10-12-95.................................47307
901.301-72  (a), (b) and (c) removed; eff. 10-12-95................47307
901.601-70  Removed; eff. 10-12-95.................................47307
901.603-70  Removed; eff. 10-12-95.................................47307

[[Page 686]]

901.603-71  Removed; eff. 10-12-95.................................47307
901.603-72  (a) designation and (b) removed; eff. 10-12-95.........47307
902.101 (Subpart 902.1)  Removed; eff. 10-12-95....................47307
903.101-3  Amended; eff. 10-12-95..................................47307
904.402  (b) amended; (c), (d) and (k) removed; eff. 10-12-95......47307
904.403  Removed; eff. 10-12-95....................................47307
904.601  Removed; eff. 10-12-95....................................47307
904.601-70  Removed; eff. 10-12-95.................................47307
904.601-71  (a), (b) and (c) designation removed; eff. 10-12-95....47307
904.702  (b) amended; eff. 10-12-95................................47307
905.205 (Subpart 905.2)  Removed; eff. 10-12-95....................47307
905.303 (Subpart 905.3)  Removed; eff. 10-12-95....................47307
906.303-1  (a) amended; eff. 10-12-95..............................47307
907.102 (Subpart 907.1)  Removed; eff. 10-12-95....................47307
907.401--907.402-70 (Subpart 907.4)  Removed; eff. 10-12-95........47307
908.802  (b) amended; eff. 10-12-95................................47307
908.7001 (Subpart 908.70)  Removed; eff. 10-12-95..................47307
908.7200--908.7201 (Subpart 908.72)  Removed; eff. 10-12-95........47307
909.404  Removed; eff. 10-12-95....................................47307
910  Removed; eff. 10-12-95........................................47307
912.503 (Subpart 912.5)  Removed; eff. 10-12-95....................47307
913.505-3  Removed; eff. 10-12-95..................................47308
914.201-5--914.201-70 (Subpart 914.2)  Removed; eff. 10-12-95......47308
914.401  Removed; eff. 10-12-95....................................47308
914.402-1  Removed; eff. 10-12-95..................................47308
915.406-5  Removed; eff. 10-12-95..................................47308
915.610  Removed; eff. 10-12-95....................................47308
915.801  Removed; eff. 10-12-95....................................47308
915.804-8  Removed; eff. 10-12-95..................................47308
915.804-70  Revised................................................18032
    Removed; eff. 10-12-95.........................................47308
    Regulation at 60 FR 18032 confirmed............................52632
915.805-5  (c)(1) revised..........................................30004
915.805-70  (a), (b), (c) and (f) removed; (d) and (e) 
        redesignated as (a) and (b); eff. 10-12-95.................47308
915.807  Removed; eff. 10-12-95....................................47308
915.808  Removed; eff. 10-12-95....................................47308
915.970-8  (d)(1) introductory text revised........................30004
916.207  Removed; eff. 10-12-95....................................47308
916.301-3  Removed.................................................18032
    Regulation at 60 FR 18032 confirmed............................52632
916.303  Removed; eff. 10-12-95....................................47308
916.603--916.603-2 (Subpart 916.6)  Removed; eff. 10-12-95.........47308
919.705-2  Removed; eff. 10-12-95..................................47308
919.705-5  Removed; eff. 10-12-95..................................47308
919.708  Removed; eff. 10-12-95....................................47308
920  Removed; eff. 10-12-95........................................47308
922.470--922.473 (Subpart 922.4)  Removed; eff. 10-12-95...........47308
923.471 (Subpart 923.4)  Added; eff. 10-13-95......................47492
924  Removed; eff. 10-12-95........................................47308
925.501 (Subpart 925.5)  Removed; eff. 10-12-95....................47308
926  Added.........................................................22300
927.200--927.207-1 (Subpart 927.2)  Added..........................11815
927.300  Added.....................................................11815
927.302  Added.....................................................11816
927.303  Added.....................................................11816
927.304  Added.....................................................11816
928.103-2  Removed; eff. 10-12-95..................................47308
928.202-1--928.202-71 (Subpart 928.2)  Removed; eff. 10-12-95......47308
931.205-18  Revised................................................30004
933.104  (b)(1) and (c) amended; (c)(1) and (2) designation 
        removed; eff. 10-26-95.....................................49516
933.170  Removed...................................................28740
933.211 (Subpart 933.2)  Removed; eff. 10-12-95....................47308
935.007  Removed; eff. 10-12-95....................................47308
935.015  Removed; eff. 10-12-95....................................47308
936.202  (a) and (b) removed; (c) through (j) redesignated as (a) 
        through (h); eff. 10-12-95.................................47308
937.207 (Subpart 937.2)  Removed; eff. 10-12-95....................47308
937.7010  Removed; eff. 10-12-95...................................47308

[[Page 687]]

937.7020  Removed; eff. 10-12-95...................................47308
937.7030  Removed; eff. 10-12-95...................................47308
939  Added.........................................................39873
    Corrected......................................................45528
942.000  Removed; eff. 10-12-95....................................47308
942.001  Removed; eff. 10-12-95....................................47308
942.002  Removed; eff. 10-12-95....................................47308
942.003  (a) revised...............................................30004
    Removed; eff. 10-12-95.........................................47308
942.101 (Subpart 942.1)Removed; eff. 10-12-95......................47308
942.101  (a)(2) removed; (a)(3) redesignated as (a)(2); (c) 
        revised....................................................30004
942.202 (Subpart 942.2)  Removed; eff. 10-12-95....................47308
942.705-1  Revised.................................................30004
942.705-3  Revised.................................................30005
942.705-4  Revised.................................................30005
942.705-5  Revised.................................................30005
942.708  Removed; eff. 10-12-95....................................47308
942.1004--942-1008 (Subpart 942.10)  Removed.......................30005
942.1401--942.1403-2 (Subpart 942.14)  Removed; eff. 10-12-95......47308
942.7003-6  Revised................................................30005
942.7004  Revised..................................................30005
943  Removed; eff. 10-12-95........................................47308
944.101 (Subpart 944.1)  Removed; eff. 10-12-95....................47308
944.202-1--944.203 (Subpart 944.2)  Removed; eff. 10-12-95.........47308
945.104-70  Removed; eff. 10-12-95.................................47308
945.304  Removed; eff. 10-12-95....................................47308
945.501  Removed; eff. 10-12-95....................................47308
945.502-70  Removed; eff. 10-12-95.................................47308
945.502-71  Removed; eff. 10-12-95.................................47308
945.502-72  Removed; eff. 10-12-95.................................47308
945.508  Removed; eff. 10-12-95....................................47308
945.570  Removed; eff. 10-12-95....................................47308
945.570-1  Removed; eff. 10-12-95..................................47308
945.570-3  Removed; eff. 10-12-95..................................47308
945.570-4  Removed; eff. 10-12-95..................................47308
945.570-5  Removed; eff. 10-12-95..................................47309
945.570-6  Removed; eff. 10-12-95..................................47309
945.570-9  Removed; eff. 10-12-95..................................47309
947.102--947.104-3 (Subpart 947.1)  Removed; eff. 10-12-95.........47309
949.108-4  Removed; eff. 10-12-95..................................47309
949.108-8  Removed; eff. 10-12-95..................................47309
949.112-1  Removed; eff. 10-12-95..................................47309
949.206-1--949.206-2 (Subpart 949.2)  Removed; eff. 10-12-95.......47309
949.303-1 (Subpart 949.3)  Removed; eff. 10-12-95..................47309
951.201 (Subpart 951.2)  Removed; eff. 10-12-95....................47309
951.7000  Revised..................................................30005
    Removed; eff. 10-12-95.........................................47309
951.7001  Revised..................................................30005
    Removed; eff. 10-12-95.........................................47309
952.226-70  Added..................................................22301
952.226-71  Added..................................................22301
952.226-72  Added..................................................22302
952.226-73  Added..................................................22302
952.227-9  Added...................................................11817
952.227-11  Added..................................................11817
952.227-13  Added..................................................11819
952.227-71  Removed................................................11822
952.251-70  Amended................................................30005
970  Authority citation revised....................................18032
970.2304  Added; eff. 10-13-95.....................................47492
970.2601 (Subpart 970.26)  Added...................................22302
970.2701  Revised..................................................11822
970.2702  Revised..................................................11822
970.2703  Added....................................................11823
970.2704  Added....................................................11823
970.2705  Added....................................................11823
970.2706  Added....................................................11823
970.3001-1  Revised................................................30006
970.3001-2  Revised................................................30006
970.3102-17  (c)(2)(i) revised; (c)(6) added.......................30006
970.5203-1  Amended; eff. 10-26-95.................................49516
970.5204-7  Added; eff. 10-26-95...................................49516
970.5204-17  Amended...............................................63647
970.5204-21  Amended; eff. 10-26-95................................49516
970.5204-22  Revised; eff. 10-26-95................................49516
970.5204-24  Amended...............................................18032
    Amended; eff. 10-26-95.........................................49517
    Regulation at 60 FR 18032 confirmed............................52632

[[Page 688]]

970.5204-39  Added; eff. 10-13-95..................................47492
970.5204-40  Added.................................................66512
970.5204-44  Added; eff. 10-26-95..................................49517
970.5204-45  Introductory text amended; eff. 10-26-95..............49518
970.5204-50  Introductory text amended; eff. 10-26-95..............49518
970.5204-71  Added.................................................11824
970.5204-72  Added.................................................11824
970.7101  (c) and (d) removed......................................28741
970.7102  (a), (b)(3) and (4) amended..............................28741
970.7103  Revised..................................................28741
970.7104  Removed; eff. 10-26-95...................................49518
970.7104-1  Removed; eff. 10-26-95.................................49518
970.7104-2  Removed; eff. 10-26-95.................................49518
970.7104-3  Removed; eff. 10-26-95.................................49518
970.7104-4  Removed; eff. 10-26-95.................................49518
970.7104-5  Removed; eff. 10-26-95.................................49518
970.7104-6  Removed; eff. 10-26-95.................................49518
970.7104-7  Removed; eff. 10-26-95.................................49518
970.7104-8  Removed; eff. 10-26-95.................................49518
970.7104-9  Removed; eff. 10-26-95.................................49518
970.7104-10  Removed; eff. 10-26-95................................49518
970.7104-11  (a)(1)(i) and (ii) revised............................18032
    Removed; eff. 10-26-95.........................................49518
    Regulation at 60 FR 18032 confirmed............................52632
970.7104-12  (f) redesignated as (g); new (f) added................22302
    Removed; eff. 10-26-95.........................................49518
970.7104-13  Removed; eff. 10-26-95................................49518
970.7104-14  Removed; eff. 10-26-95................................49518
970.7104-15  Removed; eff. 10-26-95................................49518
970.7104-16  Removed; eff. 10-26-95................................49518
970.7104-17  Removed; eff. 10-26-95................................49518
970.7104-18  Removed; eff. 10-26-95................................49518
970.7104-19  Removed; eff. 10-26-95................................49518
970.7104-20  Removed; eff. 10-26-95................................49518
970.7104-21  Removed; eff. 10-26-95................................49518
970.7104-22  Removed; eff. 10-26-95................................49518
970.7104-23  Removed; eff. 10-26-95................................49518
970.7104-24  Removed; eff. 10-26-95................................49518
970.7104-25  Removed; eff. 10-26-95................................49518
970.7104-26  Removed; eff. 10-26-95................................49518
970.7104-27  Removed; eff. 10-26-95................................49518
970.7104-28  Removed; eff. 10-26-95................................49518
970.7104-29  Removed; eff. 10-26-95................................49518
970.7104-30  Removed; eff. 10-26-95................................49518
970.7104-31  Removed; eff. 10-26-95................................49518
970.7104-32  Removed; eff. 10-26-95................................49518
970.7104-33  Revised...............................................30006
    Removed; eff. 10-26-95.........................................49518
970.7104-34  Removed; eff. 10-26-95................................49518
970.7104-35  Removed; eff. 10-26-95................................49518
970.7104-36  Removed; eff. 10-26-95................................49518
970.7104-37  Removed; eff. 10-26-95................................49518
970.7104-38  Removed; eff. 10-26-95................................49518
970.7104-39  Removed; eff. 10-26-95................................49518
970.7104-40  Removed; eff. 10-26-95................................49518
970.7104-41  Removed; eff. 10-26-95................................49518
970.7104-42  Removed; eff. 10-26-95................................49518
970.7104-43  Removed; eff. 10-26-95................................49518
970.7104-44  Removed; eff. 10-26-95................................49518

[[Page 689]]

970.7104-45  Removed; eff. 10-26-95................................49518
970.7104-46  Removed; eff. 10-26-95................................49518
970.7104-47  Removed; eff. 10-26-95................................49518
970.7106  Removed..................................................28741
970.7107  Removed..................................................28741
970.7310--970.7330 (Subpart 970.73)  Added.........................66515
971.200--971.203 (Subpart 971.2)  Removed; eff. 10-12-95...........47309
971.300--971.301 (Subpart 971.3)  Removed; eff. 10-12-95...........47309
Chapter 12
1215.413-2  (f) revised; interim...................................55802
1252.217-81  Amended; interim......................................55802
1253.303 (Subpart 1253.3)  Appendix amended; interim...............55802
Chapter 13
1301.201-1 (Subpart 1301.2)  Removed...............................47309
1301.301--1301.303 (Subpart 1301.3)  Removed.......................47309
1301.402 (Subpart 1301.4  Removed..................................47309
1301.501 (Subpart 1301.5)  Removed.................................47309
1301.601  Removed..................................................47309
1301.601-70  Removed...............................................47309
1301.603  Removed..................................................47309
1301.603-70  (a)(2) and (3) removed; (a)(4) redesignated as (a)(2)
                                                                   47309
1301.603-71  Removed...............................................47309
1302  Removed......................................................47309
1304  Removed......................................................47309
1305  Removed......................................................47309
1306  Removed......................................................47309
1307  Removed......................................................47309
1308  Removed......................................................47309
1309.470--1309.470-7 (Subpart 1309.4)  Revised.....................47309
1314  Removed......................................................47309
1315.501  Removed..................................................47309
1315.504  (a) removed; (b) and (c) redesignated as (a) and (b).....47309
1315.506  (a), (b) and (c) removed; (d) through (g) redesignated 
        as (a) through (d).........................................47309
1315.608--1315.612 (Subpart 1315.6)  Removed.......................47309
1315.804-3  Removed................................................47309
1315.805-70  (a) and (b) removed; (c) redesignated as (a)..........47309
1316.306 (Subpart 1316.3)  Removed.................................47309
1316.603-3 (Subpart 1316.6)  Removed...............................47309
1317.402 (Subpart 1317.4)  Removed.................................47309
1317.502 (Subpart 1317.5)  Removed.................................47309
1319.201  Removed..................................................47310
1319.705-5  Removed................................................47310
1319.7001  Removed.................................................47310
1319.7002  (b) removed.............................................47310
1322  Removed......................................................47310
1324  Removed......................................................47310
1325  Removed......................................................47310
1331  Removed......................................................47310
1332.402 (Subpart 1332.4)  Removed.................................47310
1332.605--1332.616 (Subpart 1332.6)  Removed.......................47310
1333.102  Removed..................................................47310
1333.104  (a)(3), (4) and (f) removed..............................47310
1333.105  (a)(2), (b) and (d) removed..............................47310
1333.209  Removed..................................................47310
1334  Removed......................................................47310
1336.602-4  Removed................................................47310
1336.603  Removed..................................................47310
1337  Removed......................................................47310
1342.102-70  (c) and (d) removed...................................47310
1345  Removed......................................................47310
Chapter 14
1404  Removed......................................................30792
1405  Removed......................................................30792
1406  Removed......................................................30792
1407  Removed......................................................30792
1409  Removed......................................................30792
1410  Removed......................................................30792
1413  Removed......................................................30792
1414  Removed......................................................30792
1415.413--1415.413-70 (Subpart 1415.4)  Removed....................53279
1415.506 (Subpart 1415.5)  Removed.................................53279
1415.607--1415.608 (Subpart 1415.6)  Removed.......................53279
1415.803--1415.804-3 (Subpart 1415.8)  Removed.....................53279
1415.902--1415.905-70 (Subpart 1415.9)  Removed....................53279
1419  Removed......................................................30792

[[Page 690]]

1420  Removed......................................................30792
1424  Removed......................................................30792
1426  Added........................................................53279
1428  Revised......................................................53280
1432  Removed......................................................30792
1433  Removed......................................................30792
1436  Removed......................................................30792
1437  Removed......................................................30792
1442  Removed......................................................30792
1452.204-71  Redesignated as 1452.226-70...........................53280
1452.204-72  Redesignated as 1452.226-71...........................53280
1452.226-70  Redesignated from 1452.204-71.........................53280
1452.226-71  Redesignated from 1452.204-72.........................53280
1452.228-70  Revised...............................................53280
1452.228-73  Introductory text revised.............................53280

                                  1996

48 CFR
                                                                   61 FR
                                                                    Page
Chapter 7
701.105  (a) amended...............................................39090
701.370  Amended...................................................39090
701.470  (b)(1) amended............................................39090
701.601  (b) revised...............................................39090
701.603-70  Amended................................................39091
702.170-3  (a) amended.............................................39091
702.170-10  (a)(1)(iv) amended.....................................39091
702.170-13  (b) corrected; eff. 10-31-96...........................51234
706.302-70  (b)(5) and (c)(4) added; (c)(1) amended................39091
706.302-71  (a)(2) and (b) corrected; eff. 10-31-96................51235
709.104-3 (Subpart 709.1)  Removed.................................39091
710  Redesignated as Part 711......................................39091
711  Redesignated from Part 710; heading revised...................39091
711.002-71  Redesignated from 711.011 and amended..................39091
711.011  Redesignated as 711.002-71................................39091
711.022-70  Redesignated from 711.070; (a) and (b)(1) amended......39091
711.070  Redesignated as 711.022-70................................39091
713  Revised.......................................................39091
715  Technical correction..........................................51235
715.604  Added.....................................................39091
715.604-70  Redesignated from 715.608-70 and revised...............39091
715.605-70  Removed................................................39091
715.608-70  Redesignated as 715.604-70.............................39091
716  Technical correction..........................................51235
716.301-3  Removed.................................................39092
716.501  Removed...................................................39092
717.700  Amended...................................................39092
719.270  (c)(1) and (d) amended....................................39092
719.271-2  (b)(8) amended..........................................39092
719.271-3  (g) amended.............................................39092
    Corrected......................................................42939
719.271-4  (c) amended.............................................39092
719.271-5  Heading, introductory text and (b) revised..............39092
719.271-6  (a) introductory text and (b)(1) amended................39092
722.103  Corrected.................................................53996
722.103-1  Redesignated from 722.103-70............................39092
722.103-2  Redesignated from 722.103-71............................39092
    Correctly redesignated from 722.103-71.........................52497
722.103-4  Redesignated from 722.103-72............................39092
    Correctly redesignated from 722.103-72.........................52497
722.103-70  Removed................................................39092
    Corrected......................................................42939
    Correctly removed..............................................51235
722.103-71  Redesignated as 722.103-2..............................39092
    Correctly redesignated as 722.103-2............................52497
722.103-72  Redesignated as 722.103-4..............................39092
    Correctly redesignated as 722.103-4............................52497
722.805-70 (Subpart 722.8)  Revised................................39092
    (b)(1)(i) and (iii) corrected..................................42939
724.170 (Subpart 724.1)  Removed...................................39093
725.403 (Subpart 725.4)  Revised...................................39093
725.701  Amended...................................................39093
725.702  (b) amended...............................................39093
725.705  (a) amended...............................................39093
725.706  (a) revised...............................................39093
726.000  Redesignated as 726.7001..................................39093
726.101--726.104 (Subpart 726.1)  Heading removed..................39093

[[Page 691]]

726.101  Redesignated as 726.7002..................................39093
726.102  Redesignated as 726.7003..................................39093
726.103  Redesignated as 726.7004..................................39093
726.104  Redesignated as 726.7005..................................39093
726.201 (Subpart 726.2)  Heading removed...........................39093
726.201  Redesignated as 726.7006..................................39093
726.301--726.302 (Subpart 726.3)  Removed; eff. 10-31-96...........51235
726.301  Redesignated as 726.7007..................................39093
726.302  Correctly redesignated as 726.7008; eff. 10-31-96.........51235
726.7001--726.7007 (Subpart 726.70)  Heading added.................39093
726.7001  Redesignated from 726.000 and amended....................39093
726.7002  Redesignated from 726.101................................39093
726.7003  Redesignated from 726.102................................39093
726.7004  Redesignated from 726.103................................39093
726.7005  Redesignated from 726.104................................39093
726.7006  Redesignated from 726.201................................39093
726.7007  Redesignated from 726.301................................39093
726.7008  Correctly redesignated from 726.302; eff. 10-31-96.......51235
726.7101--726.7102 (Subpart 726.71)  Added.........................39093
732.111 (Subpart 732.1)  Added.....................................39094
732.402  (e) revised...............................................39094
732.406-71  (a) and (b) revised....................................39094
732.406-72  (a) amended; (b)(6) added..............................39094
733.1--733.103-73 (Subpart 733.1)  Redesignated from 733.7001--
        733.7008 (Subpart 733.70) and revised......................39094
733.103-71  (b) and (c) corrected; eff. 10-31-96...................51235
733.103-72  (b) correctly revised; eff. 10-31-96...................51235
733.270-1  Correctly designated; eff. 10-31-96.....................51235
733.270-2  Correctly designated; eff. 10-31-96.....................51235
733.2701--733.2702 (Subpart 733.27)  Redesignated from 733.7101--
        733.7102 (Subpart 733.71)..................................39095
733.7001--733.7008 (Subpart 733.70)  Redesignated as 733.1--
        733.103-73 (Subpart 733.1).................................39094
733.7101--733.7102 (Subpart 733.71)  Redesignated as 733.2701--
        733.2702 (Subpart 73.27)...................................39095
736.602-5  Heading revised.........................................39095
737  Technical correction..........................................51235
737.205-70--737.270 (Subpart 737.2)  Removed.......................39095
752.203-1  Removed.................................................39095
752.209-70  Amended................................................39095
752.210-70  Redesignated as 752.211-70.............................39095
752.211-70  Redesignated from 752.210-70...........................39095
752.219-8  Amended.................................................39095
752.7004  Amended..................................................39095
752.7006  Amended..................................................39095
752.7007  Amended..................................................39095
752.7012  Revised..................................................39095
752.7017  Amended..................................................39096
752.7018  Amended..................................................39096
752.7019  Amended..................................................39096
752.7028  Amended..................................................39096
    Corrected......................................................42939
    Corrected; eff. 10-31-96.......................................51235
Chapter  7 Appendix A amended......................................39096
Chapter 8
801  Authority citation revised..............................1527, 20491
801.104  Removed...................................................20491
801.104-1  Removed.................................................20491
801.104-3  Removed.................................................20491
801.201  Removed...................................................20491
801.301  (c) removed...............................................20491
801.403  (b) amended...............................................20491
801.470  Removed...................................................20491
801.602  Revised....................................................1526
801.602-3  (a)(3)(i) and (ii) amended..............................11585
801.602-70  Amended................................................11585
801.602-71  Amended................................................11585
    (b) heading revised; (b)(1), (2) and (3) amended...............11586
801.602-72  (d)(6)(iv) amended.....................................11586
    (e)(5) amended.................................................20491
801.602-73  Amended................................................11586
801.603-71  Amended................................................11586
801.670-5  (a)(2) and (b) amended..................................11586

[[Page 692]]

801.670-6  Amended.................................................11586
    Removed........................................................20491
801.680  (b) amended...............................................11586
802  Authority citation revised.....................................1527
802.100  (b) revised; (c) added.....................................1527
803  Authority citation revised..............................1527, 20491
803.101-3  (a) amended; (c) removed; (d) redesignated as (c).......20491
803.104-5  Removed.................................................20491
803.104-9  Removed.................................................20491
803.104-11  Removed................................................20491
803.104-12  Removed................................................20491
803.203  (b) amended................................................1527
803.301--803.303 (Subpart 803.3)  Heading amended..................20491
803.301  Removed...................................................20491
803.303  Amended....................................................1527
803.408  Removed...................................................20491
803.408-1  Removed.................................................20491
803.409  (a) and (b) designation removed...........................20491
803.603 (Subpart 803.6)  Removed...................................20491
804  Authority citation revised....................................20491
804.101  (a) and (b) designation removed...........................20492
805  Authority citation revised....................................20491
805.202  Amended...................................................20492
805.207  (a), (b) designation, (1), (2) and (3) removed............20492
806  Authority citation revised..............................1527, 20491
806.302-3  Amended.................................................20492
806.302-5  Amended.................................................20492
806.302-7  (b) amended.............................................20492
806.303  Removed...................................................20492
806.303-1  Removed.................................................20492
806.304  (a) amended...............................................20492
806.501  (a) amended................................................1527
806.502  (d) and (e) removed.......................................20492
806.570  (a), (b) designation and (c) removed; (b)(1) through (5) 
        redesignated as (a) through (e)............................20492
808  Authority citation revised....................................20491
808.001  (a)(2) removed; (a)(3) through (10) redesignated as 
        (a)(2) through (9).........................................20492
808.304-1--808.304-70 (Subpart 808.3)  Removed.....................20492
808.405-5  Removed.................................................20492
810  Authority citation revised....................................20491
810.007  (a)(2)(i) removed; (a)(2)(ii) amended; (a)(2)(ii) and 
        (iii) redesignated as (a)(2)(i) and (ii)...................20492
812  Authority citation revised....................................20491
812.503 (Subpart 812.5)  Removed...................................20492
813  Authority citation revised....................................20491
813.103 (Subpart 813.1)  Removed...................................20492
814.403  Amended...................................................11586
814.404-70  Amended................................................11586
814.406-3  Amended.................................................11586
814.406-4  Amended.................................................11586
814.407-71  (a) introductory text amended..........................11586
815  Authority citation revised....................................20491
815.502  Removed...................................................20492
815.800  Removed...................................................20492
815.7001---815.7002 (Subpart 815.70)  Removed......................20492
816  Authority citation revised....................................20491
816.102  (a) and (c) removed; (b), (d) and (e) redesignated as 
        (a), (b) and (c); new (a) and new (c) amended..............20492
816.306 (Subpart 816.3)  Removed...................................20492
816.603 (Subpart 816.6)  Removed...................................20492
820  Removed.......................................................20492
822  Authority citation revised....................................20491
822.471  Removed...................................................20492
828  Authority citation revised....................................20491
828.307-1  Removed.................................................20492
833  Authority citation revised....................................20491
833.102  (a) amended...............................................11586
833.103  Amended...................................................11586

[[Page 693]]

    (a), (b)(1), (4) and (7)(vii) removed; (b) through (f) 
redesignated as (a) through (e); new (a)(2), (3), (5), (6) and (7) 
redesignated as (a)(1) through (5); new (a)(5)(viii), new (ix) and 
new (x) redesignated as (a)(5)(vii), (viii) and (ix)...............20492
833.104  Amended...................................................11586
833.105  (b) amended...............................................11586
833.211  (d) and (e) removed.......................................20492
833.212  Amended...................................................11586
834  Removed.......................................................20492
836  Authority citation revised....................................20491
836.202  (a) removed; introductory text redesignated as (a)........20492
836.208  Amended...................................................11586
836.209  Amended...................................................11586
836.211  (b) amended...............................................11586
    (a), (b), (c) designation and (d) removed......................20492
836.371  Heading amended...........................................11587
    (a) amended....................................................20492
836.601  Amended...................................................11587
    Removed........................................................20492
836.602-1  (c) removed; (d) redesignated as (c)....................20493
836.602-2  (a) and (b) amended.....................................11587
836.602-3  Amended.................................................11587
    Removed........................................................20493
836.602-4  Amended.................................................11587
836.602-5  Amended.................................................11587
836.606-70  Amended................................................20493
836.606-71  Amended................................................20493
836.606-72  Amended................................................11587
836.606-73  (a) amended............................................20493
837  Authority citation revised.............................20491, 52709
837.104  (a) amended...............................................20493
837.200  Removed...................................................20493
837.204  Removed...................................................20493
837.205  Removed...................................................20493
837.200--837.271-5 (Subpart 837.2)  Appendixes A and B removed.....20493
837.271-5  Removed.................................................20493
837.403 (Subpart 837.4)  Added.....................................52709
837.7002  Amended..................................................20493
846  Authority citation revised....................................20491
846.302  Removed...................................................20493
846.403  Removed...................................................20493
846.408-72  Removed................................................20493
852.210-70  Amended................................................11587
852.210-76  Amended................................................11587
852.219-70  Amended................................................11587
852.236-83  Amended................................................11587
852.236-88  Amended................................................11587
852.236-91  Amended................................................11587
852.237-7  Added...................................................52710
871  Authority citation revised....................................20493
871.101  Revised...................................................20493
871.102  (a) amended...............................................20493
    (b) through (e) amended........................................20494
871.103  Removed...................................................20494
871.105  Removed...................................................20494
871.106  (b) amended...............................................20494
871.200  Revised...................................................20494
871.201-3  Amended.................................................20494
871.207  (b)(2) amended............................................20494
Chapter 9
901  Revised.......................................................41704
904.7103  (a) and (b) amended......................................21976
905.403--905.404-1 (Subpart 905.4)  Removed........................41705
906.302  Removed...................................................41705
906.302-70  Removed................................................41705
906.303  Removed...................................................41750
906.303-1  (a) amended.............................................21976
    Removed........................................................41750
908.303--908.307 (Subpart 908.3)  Removed..........................41705
908.802 (Subpart 908.8)  Revised...................................41705
908.1102--908.1170 (Subpart 908.11)  Revised.......................41705
909.400--909.407-3 (Subpart 909.4)  Revised........................39857
909.405  Heading corrected.........................................41684
909.407-3  Heading corrected.......................................41684
911  Redesignated from Part 912; heading revised...................21976
911.600  Redesignated from 912.300 and amended.....................21976
    Corrected......................................................30823
911.602  Redesignated from 912.302.................................21976
911.604  Redesignated from 912.304; (a) through (e) amended........21976
912  Redesignated as Part 911......................................21976
912.300  Redesignated as 911.600...................................21976
912.302  Redesignated as 911.602...................................21976
912.304  Redesignated as 911.604...................................21976
913  Heading revised...............................................21976

[[Page 694]]

913.505-1  (a)(2) and (b)(2) amended...............................21976
915.502--915.507 (Subpart 915.5)  Revised..........................41705
915.610--915.613 (Subpart 915.6)  Removed..........................41706
915.970-8  (f)(1) and (2)(i) amended; (f)(2)(ii) removed; 
        (f)(2)(iii) redesignated as (f)(2)(ii).....................21976
    Revised........................................................41706
915.971-3  (b)(viii) amended.......................................21976
916.405  Removed...................................................41706
917.602  Added; interim............................................32586
917.605  Revised; interim..........................................32586
917.7000--917.7001 (Subpart 917.70)  Revised.......................41706
917.7200--917.7201-1 (Subpart 917.72)  Revised.....................41706
917.7300--917.7301-1 (Subpart 917.73)  Revised.....................41707
917.7401--917.7403 (Subpart 917.74)  Revised.......................41707
917.7500--917.7502 (Subpart 917.75)  Removed.......................41708
919  Heading revised...............................................21976
919.201  (c) amended...............................................21976
919.501  (c) amended...............................................21977
919.602-1  (a)(2) amended..........................................21977
919.705-6 (Subpart 919.7)  Heading revised.........................21977
922.805  Removed...................................................41708
922.7000--922.7001 (Subpart 922.70)  Removed.......................41708
925.901  Amended...................................................21977
926.7003  Amended..................................................21977
928.101-1--928.103-70 (Subpart 928.1)  Revised.....................41708
932.102  Revised...................................................41708
932.703-1 (Subpart 932.7)  Removed.................................41708
932.802  Removed...................................................41708
932.805  Removed...................................................41708
932.970 (Subpart 932.9)  Revised...................................41708
932.7000  Removed..................................................41708
932.7001  Removed..................................................41708
933.103--933.106 (Subpart 933.1)  Revised..........................41708
933.106  Amended...................................................21977
935.016  Revised...................................................41709
935.016-1  Revised.................................................41709
935.016-2  Revised.................................................41709
935.016-3  Removed.................................................41709
935.016-4  Removed.................................................41709
935.016-5  Removed.................................................41709
935.016-6  Removed.................................................41709
935.016-7  Removed.................................................41709
935.016-8  Revised.................................................41710
935.016-9  Removed.................................................41709
936.601  Removed...................................................41710
936.602-2  Removed.................................................41710
936.602-3  Removed.................................................41710
936.602-4  Removed.................................................41710
936.603  Removed...................................................41710
936.605  Removed...................................................41710
936.606  Removed...................................................41710
936.7200--936.7202 (Subpart 936.72)  Removed.......................41710
941  Added.........................................................41710
942.705-1  Revised.................................................41710
942.705-3  Revised.................................................41710
942.705-4  Revised.................................................41710
942.705-5  Revised.................................................41710
942.7000--942.7004 (Subpart 942.70)  Removed.......................41711
945.505-5  Removed.................................................41711
945.505-14  Removed................................................41711
950.7101  (c)(2) amended...........................................21977
952.211  Redesignated from 952.212.................................21977
952.211-70  Redesignated from 952.212-70 and amended...............21977
    Corrected......................................................30823
952.211-71  Redesignated from 952.212-71 and amended...............21977
    Corrected......................................................30823
952.211-72  Redesignated from 952.212-72...........................21977
    Corrected......................................................30823
952.211-73  Redesignated from 952.212-73...........................21977
    Corrected......................................................30823
952.212  Redesignated as 952.211...................................21977
952.212-70  Redesignated as 952.211-70.............................21977
952.212-71  Redesignated as 952.211-71.............................21977
952.212-72  Redesignated as 952.211-72.............................21977
952.212-73  Redesignated as 952.211-73.............................21977
952.214  Removed...................................................41711
952.215  Removed...................................................41711
952.215-22  Removed................................................41711
952.215-23  Removed................................................41711
952.226-70  (c) and (d) amended....................................21977
    Corrected......................................................30823
952.226-71  (b) amended............................................21977

[[Page 695]]

    Corrected......................................................30823
952.226-72  Corrected..............................................30823
952.226-73  Corrected..............................................30823
952.233-2  Revised.................................................41711
952.233-4  Added...................................................41711
952.233-5  Added...................................................41711
952.250-70  (h) amended............................................21977
    Corrected......................................................30823
952.251-70  Amended................................................41711
970.226-72  (c)(2) amended.........................................21977
970.0001  Removed; interim.........................................32586
970.1702-1--970.1702-2 (Subpart 970.17)  Added; interim............32586
970.1901 (Subpart 970.19)  Heading revised.........................21977
970.5203-2  Removed................................................21977
970.5204-9  Amended................................................21977
    Corrected......................................................30823
970.5204-13  Amended...............................................21977
    Corrected......................................................30823
970.5204-14  Amended...............................................21978
    Corrected......................................................30823
970.5204-44  Amended...............................................21978
    Corrected......................................................30823
970.5204-73  Added; interim........................................32587
970.5204-74  Added; interim........................................32587
971  Removed.......................................................41711
Chapter 12
1201.102  Redesignated as 1201.103; eff. 10-25-96..................50249
1201.103  Redesignated as 1201.104; new 1201.103 redesignated from 
        1201.102; eff. 10-25-96....................................50249
1201.104  Redesignated as 1201.105; new 1201.104 redesignated from 
        1201.103; eff. 10-25-96....................................50249
1201.104-1  Redesignated as 1201.105-1; eff. 10-25-96..............50249
1201.104-2  Amended; eff. 10-25-96.................................50248
    Redesignated as 1201.105-2; eff. 10-25-96......................50249
1201.104-3  Redesignated as 1201.105-3; eff. 10-25-96..............50249
1201.105  Redesignated as 1201.106; new 1201.105 redesignated from 
        1201.104; eff. 10-25-96....................................50249
1201.105-1  Redesignated from 1201.104-1; eff. 10-25-96............50249
1201.105-2  Redesignated from 1201.104-2; eff. 10-25-96............50249
1201.105-3  Redesignated from 1201.104-3; eff. 10-25-96............50249
1201.106  Redesignated from 1201.105; eff. 10-25-96................50249
1201.403  Revised; eff. 10-25-96...................................50249
1201.602-3--1201.603-1 (Subpart 1201.6)  Heading revised; eff. 10-
        25-96......................................................50249
1202.1  (i)(7) revised; eff. 10-25-96..............................50249
1205.101  (a)(2) removed; (a)(2)(iii) added; eff. 10-25-96.........50249
1209.406--1209.407-3 (Subpart 1209.4)  Removed; eff. 10-25-96......50249
1209.507  Revised; eff. 10-25-96...................................50249
1210  Heading revised; eff. 10-25-96...............................50249
1210.004  Removed; eff. 10-25-96...................................50249
1210.004-70  Removed; eff. 10-25-96................................50249
1210.011  Removed; eff. 10-25-96...................................50249
1210.011-90  Removed; eff. 10-25-96................................50249
1211  Added; eff. 10-25-96.........................................50249
1212  Heading revised; eff. 10-25-96...............................50249
    Heading correctly revised; eff. 10-25-96.......................53677
    Clarification..................................................53677
    Correctly removed; eff. 10-25-96...............................54490
1213  Clarification................................................53677
1213.107-90  Amended; eff. 10-25-96................................50249
1213.507-90  Amended; eff. 10-25-96................................50249
1213.7100--1213.7101 (Subpart 1213.71)  Added........................391
1215.407  Removed; eff. 10-25-96...................................50249
1215.413-2  Regulation at 60 FR 55802 confirmed......................274
1215.804  Removed; eff. 10-25-96...................................50249
1215.804-2  Removed; eff. 10-25-96.................................50249
1215.804-6  Heading revised; eff. 10-25-96.........................50249
1216.505 (Subpart 1216.5)  Added; eff. 10-25-96....................50249
1219  Heading revised; eff. 10-25-96...............................50249
1219.201  (c) amended; eff. 10-25-96...............................50249
1219.708--1219.708-70 (Subpart 1219.7)  Heading revised; eff. 10-
        25-96......................................................50249

[[Page 696]]

1219.1005--1219.1006 (Subpart 1219.10)  Appendix A redesignated 
        from 1219.1006 Appendix A; eff. 10-25-96...................50250
1219.1006  Appendix A redesignated as Subpart 1219.10 Appendix A; 
        eff. 10-25-96..............................................50250
1220  Heading revised; eff. 10-25-96...............................50250
1224.000  Removed; eff. 10-25-96...................................50250
1224.103  Added; eff. 10-25-96.....................................50250
1233.214  (d) removed; (b) and (c) redesignated as (c) and (d); 
        new (c) introductory text and new (d) revised; eff. 10-25-
        96.........................................................50250
1237.104-90 (Subpart 1237.104)  Added; eff. 10-25-96...............50250
1237.110 (Subpart 1237.1)  Heading revised; eff. 10-25-96..........50250
1237.7000--1237.7003 (Subpart 1237.70)  Added........................392
1247.104-370  Amended; eff. 10-25-96...............................50250
1247.305-70  (a) through (f) amended; eff. 10-25-96................50250
1247.305-71  Amended; eff. 10-25-96................................50250
1252.210-70  Redesignated as 1252.211-70; eff. 10-25-96............50250
1252.210-71  Redesignated as 1252.211-71; eff. 10-25-96............50250
1252.211-70  Redesignated from 1252.210-70; eff. 10-25-96..........50250
1252.211-71  Redesignated from 1252.210-71; eff. 10-25-96..........50250
1252.217-81  Regulation at 60 FR 55802 confirmed.....................274
1252.237-71  Added...................................................392
1252.237-72  Added...................................................392
1252.247-1  Redesignated as 1252.247-70; eff. 10-25-96.............50250
1252.247-2  Redesignated as 1252.247-71; eff. 10-25-96.............50250
1252.247-3  Redesignated as 1252.247-72; eff. 10-25-96.............50250
1252.247-4  Redesignated as 1252.247-73; eff. 10-25-96.............50250
1252.247-5  Redesignated as 1252.247-74; eff. 10-25-96.............50250
1252.247-6  Redesignated as 1252.247-75; eff. 10-25-96.............50250
1252.247-7  Redesignated as 1252.247-76; eff. 10-25-96.............50250
1252.247-8  Redesignated as 1252.247-77; eff. 10-25-96.............50250
1252.247-70  Redesignated from 1252.247-1; eff. 10-25-96...........50250
1252.247-71  Redesignated from 1252.247-2; eff. 10-25-96...........50250
1252.247-72  Redesignated from 1252.247-3; eff. 10-25-96...........50250
1252.247-73  Redesignated from 1252.247-4; eff. 10-25-96...........50250
1252.247-74  Redesignated from 1252.247-5; eff. 10-25-96...........50250
1252.247-75  Redesignated from 1252.247-6; eff. 10-25-96...........50250
1252.247-76  Redesignated from 1252.247-7; eff. 10-25-96...........50250
1252.247-77  Redesignated from 1252.247-8; eff. 10-25-96...........50250
1253.303 (Subpart 1253.3)  Regulation at 60 FR 55802 confirmed.......274
    Appendix amended.................................................393
    Appendix amended; eff. 10-25-96................................50250
Chapter 14
1403.101--1403.101-3 (Subpart 1403.1)  Removed...................5519...
1403.203--1403.203-70 (Subpart 1403.2)  Removed..................5519...
1403.570--1403.570-3 (Subpart 1403.5)  Added.....................5519...
1425  Revised...................................................15390...
1425.202  Removed................................................5520...
1425.204  Removed................................................5520...
1452.203-70  Added...............................................5520...
1452.204-70  Removed............................................31053...
1452.210-70  Removed............................................31053...
1452.224-1  Removed.............................................31053...
1452.225-70  Revised............................................15390...
1452.233-2  Removed.............................................31053...
1452.236-70  Removed............................................31053...
1452.237-70  Removed............................................31053...
1453  Removed................................................31054......

                                  1997

  (Regulations published from January 1, 1997, through October 1, 1997)

48 CFR
                                                                   62 FR
                                                                    Page
Chapter 7
Chapter  7 Nomenclature change.....................................40466
    Nomenclature correction........................................45334
701.105  (a) table amended.........................................40466
701.373  (b) amended...............................................40466
701.376-3  Revised.................................................40466

[[Page 697]]

701.601  (a) and (b) amended; (b)(3) removed; (b)(4) and (5) 
        redesignated as (b)(3) and (4).............................40466
701.602-1  Added...................................................40466
701.704  Amended...................................................40466
702.170-3  (a) amended.............................................40466
702.170-10  (a)(1) amended; (a)(1)(ii) removed; (a)(1)(iii) and 
        (iv) redesignated as (a)(1)(ii) and (iii)..................40466
702.170-15  Amended................................................40466
702.170-17  Added..................................................40466
703.104-11  Added..................................................40467
703.403 (Subpart 703.4)  Removed...................................40467
704  Technical correction..........................................47532
704.404  Amended...................................................40467
704.803  Removed...................................................40467
705.002  Existing text designated as (a); (b) added................40467
705.207  (a) amended...............................................40467
706.302-5  Amended.................................................40467
706.302-70  (c)(4) revised.........................................40467
706.302-71  (a) revised; (b)(1) amended............................40467
708  Removed.......................................................40467
709.402  Removed...................................................40467
709.403  Added.....................................................40467
709.503  Amended...................................................40467
711.002-70  Redesignated from 711.022-70; (b)(1) and (3) amended 
                                                                   40467
711.002-71  Amended................................................40466
    Corrected......................................................45334
711.022-70  Redesignated as 711.002-70.............................40467
715.413-2  (b) revised; (c) amended................................40467
    Corrected......................................................47532
715.613-71  (a), (b) and (c) revised; (d) and (e) removed; (f) 
        redesignated as (d); new (d)(3)(i) and new (4) amended.....40467
    (c)(1) correctly revised.......................................45334
    (c)(2) correctly revised.......................................47532
719.270  Amended...................................................40466
    (d) amended; (k) removed.......................................40468
719.271-2  Amended.................................................40466
    (b)(8) amended.................................................40468
719.271-3  (j) amended.............................................40468
719.271-6  Amended.................................................40466
    (a) introductory text and (3) amended..........................40468
722.170  Amended...................................................40466
    Corrected......................................................45334
722.805-70  (d)(3) amended.........................................40468
725.701  Revised...................................................40468
725.703  Amended...................................................40466
725.704  Revised...................................................40468
725.705  Revised...................................................40468
725.706  (a) revised...............................................40468
726.7001  Amended..................................................40468
726.7003  Introductory text and (c) amended........................40468
726.7005  Amended..................................................40468
726.7006  (a) amended..............................................40468
726.7007  (a) and (b) amended......................................40468
    (b) corrected..................................................47532
728.305-70  Amended................................................40466
728.307-2  Amended.................................................40466
    Corrected......................................................45334
728.309  Amended...................................................40466
    Corrected......................................................45334
728.313  Amended...................................................40466
    Corrected......................................................45334
731.205-6  (d) amended.............................................40468
731.371  (b)(1) amended............................................40469
732.401  (a) amended...............................................40469
733.270-2  (e) amended.............................................40469
750.7101  (a) amended..............................................40469
750.7109-3  Amended................................................40469
750.7110  Revised..................................................40469
750.7110-1  Revised................................................40469
750.7110-2  Revised................................................40469
750.7110-3  Revised................................................40469
750.7110-4  Revised................................................40469
750.7110-5  Revised................................................40469
    Corrected......................................................47532
752.200  Amended...................................................40469
752.204-2  Amended.................................................40469
752.209-70  Removed................................................40469
752.211-70  Amended................................................40466
    Corrected......................................................45334
752.219-8  Amended.................................................40469
752.225-9  Amended.................................................40470
752.225-70  Added..................................................40470
    Corrected......................................................45334
752.225-71  Added..................................................40470
    Corrected...............................................45334, 47532
752.226-1  Introductory text amended...............................40470
752.226-2  Amended.................................................40470
752.226-3  Introductory text amended...............................40470
752.228-7  Amended.................................................40470
752.245-70  Amended................................................40470
752.245-71  Introductory text revised..............................40470
752.7001  Revised..................................................40470
    Corrected...............................................45334, 47532

[[Page 698]]

752.7002  Amended..................................................40466
    Corrected......................................................45334
752.7003  Amended..................................................40466
    Corrected......................................................45334
752.7004  Amended..................................................40466
    Revised........................................................40470
    Corrected......................................................45334
752.7007  Amended..................................................40470
752.7008  Introductory text amended................................40470
752.7009  Amended..................................................40466
752.7010  Introductory text amended................................40470
752.7015  Amended..................................................40471
    Corrected......................................................45334
752.7017  Removed..................................................40471
752.7027  Amended..................................................40471
752.7029  Introductory text amended................................40471
752.7033  Amended..................................................40471
    Corrected......................................................45334
753.107  Amended...................................................40471
Chapter  7 Appendix D revised......................................39453
    Appendixes A, C, G and H removed...............................40471
    Appendix J revised.............................................42929
Chapter 8
807  Authority citation revised....................................18300
807.302  Removed...................................................18300
807.304-72  Removed................................................18300
852  Authority citation revised....................................18300
852.207-71  Removed................................................18300
852.207-72  Removed................................................18300
Chapter 9
901.105  Amended (OMB numbers).....................................34861
904.601-71 (Subpart 904.6)  Removed.................................2312
904.702  (b) amended................................................2312
904.7003  (d) revised..............................................42073
904.7005  (a) revised..............................................42074
904.7103  (a) revised..............................................42074
906.303-70  Removed.................................................2312
908.7121  (b) amended...............................................2312
909.104-1  (h) revised.............................................42074
909.503--909.507-2 (Subpart 909.5)  Revised........................40751
915.401  Amended....................................................2312
917.600  Amended...................................................34861
917.601  Added.....................................................34861
917.602  Regulation at 61 FR 32586 confirmed.......................34873
917.605  Regulation at 61 FR 32586 confirmed.......................34873
923.570-2  (a) revised.............................................42074
923.570-3  (b)(2) and (3) revised; (b)(4) removed..................42074
923.7002  (d) amended...............................................2312
925  Authority citation revised.....................................2311
926.7007  (d) revised..............................................42074
926.7101--926.7104 (Subpart 926.71)  Added.........................34861
945.608-2  (b)(1)(ii) revised.......................................2312
950.7101  (c)(2) removed; (c)(1) redesignated as (c)...............34861
952  Authority citation revised..............................2311, 34862
952.202-1  Amended; (b) introductory text revised...................2312
952.204-2  Amended...........................................2312, 42074
952.204-71  Amended.................................................2312
952.204-72  Amended.................................................2312
952.204-73  Amended..........................................2312, 42074
952.209-8  Added...................................................40752
952.209-70  Removed................................................40752
952.209-72  Revised................................................40752
952.211-72  Removed.................................................2312
952.211-73  Removed.................................................2312
952.216-15  Amended.................................................2312
952.223-71  Heading revised........................................34862
952.223-74  Removed................................................34862
952.223-75  Introductory text revised..............................34862
952.224-70  Amended.................................................2312
952.226-73  Amended................................................42074
952.226-74  Added..................................................34862
952.227-13  Amended................................................42074
952.227-75  Amended.................................................2312
952.227-76  Amended.................................................2312
952.227-77  Amended.................................................2312
952.227-78  Amended.................................................2312
952.227-79  Amended.................................................2312
952.227-80  Removed................................................42075
952.227-81  Removed................................................42075
952.227-82  Amended.................................................2312
952.227-83  Introductory text revised..............................42075
952.235-70  Amended.................................................2312
952.236-71  Amended.................................................2312
952.247-70  Amended.................................................2312
952.249-70  Amended.................................................2312
970.0001  Regulation at 61 FR 32586 confirmed......................34873
970.0404-3  (a) and (b) amended.....................................2312
970.0406  Removed...................................................2312

[[Page 699]]

970.0407  Removed..................................................34862
970.0407-1  Added..................................................34862
970.0407-2  Added..................................................34862
970.0407-3  Added..................................................34862
970.0470  Added....................................................34862
970.0470-1  Added..................................................34862
970.0470-2  Added..................................................34862
970.0803  Redesignated as 970.4100..................................2312
970.0905  Revised..................................................40753
970.1001  Revised..................................................34862
970.1002  Heading revised..........................................34863
970.1507  Added....................................................34863
970.1507-1  Added..................................................34863
970.1507-2  Added..................................................34863
970.1507-3  Added..................................................34864
970.1509-2  (a) revised............................................34864
970.17  Regulation at 61 FR 32586 confirmed........................34873
970.1702-1  Regulation at 61 FR 32586 confirmed....................34873
970.1702-2  Regulation at 61 FR 32587 confirmed....................34873
970.2273  (a)(3) through (6) and (c)(1) introductory text amended 
                                                                    2312
970.2275  Added....................................................34864
970.2275-1  Added..................................................34864
970.2275-2  Added..................................................34864
970.2302-2  (c), (d) and (e) removed...............................34864
970.2305-4  (a) revised............................................42075
970.2305-5  (b)(2) revised.........................................42075
970.2601  Existing text designated as (a); (b) added...............34864
970.260-1  Added...................................................34864
970.260-2  Added...................................................34864
970.2830  Added....................................................34864
970.2903  Revised...................................................2312
970.3101-3  (a)(1) revised.........................................34865
970.3102-21  Revised...............................................34865
970.3102-22  Removed...............................................34865
970.3103  (d) added................................................34865
970.4100 (Subpart 970.41)  Heading added............................2312
970.4100  Redesignated from 970.0803; (a) and (c) amended; (d) 
        removed.....................................................2312
970.4501 (Subpart 970.45)  Added...................................34865
970.5204-2  Revised................................................34865
970.5204-12  Amended................................................2313
970.5204-13  Amended; introductory text revised....................34866
970.5204-14  Amended; introductory text revised....................34866
970.5204-15  Amended................................................2313
970.5204-16  Amended................................................2313
    Amended; introductory text revised.............................34867
970.5204-17  Amended................................................2313
970.5204-18  Amended................................................2313
    Removed........................................................34867
970.5204-20  Amended................................................2313
970.5204-21  Amended................................................2313
    Amended; introductory text revised.............................34867
970.5204-23  Introductory text amended..............................2313
970.5204-24  Amended................................................2313
970.5204-26  Amended................................................2313
    Removed........................................................34868
970.5204-31  Amended................................................2313
    Revised........................................................34868
970.5204-32  (a) and (b) amended....................................2313
    Removed........................................................34869
970.5204-33  (a) and (b) amended....................................2313
970.5204-35  Amended................................................2313
970.5204-38  Amended................................................2313
970.5204-41  Amended................................................2313
    Removed........................................................34869
970.5204-43  Amended................................................2313
970.5204-44  (b)(11) amended........................................2313
    (b)(15) revised................................................40753
970.5204-45  Amended................................................2313
970.5204-50  Removed................................................2313
970.5204-52  Revised................................................2313
970.5204-54  Amended................................................2313
970.5204-55  Amended................................................2313
    Removed........................................................34869
970.5204-56  Amended................................................2313
    Removed........................................................34869
970.5204-57  Amended.........................................2313, 42075
970.5204-60  Amended................................................2313
970.5204-61  Amended................................................2313
    Amended; introductory text revised.............................34869
970.5204-62  Removed...............................................34869
970.5204-73  Regulation at 61 FR 32587 confirmed...................34873
970.5204-74  Regulation at 61 FR 32587 confirmed...................34873
970.5204-75  Added.................................................34869
970.5204-76  Added.................................................34870
970.5204-77  Added.................................................34870
970.5204-78  Added.................................................34870
970.5204-79  Added.................................................34871
970.5204-80  Added.................................................34871
970.7105  (a)(3) amended............................................2313

[[Page 700]]

Chapter 12
1201.301-70  (a)(4) removed; (a)(5) redesignated as (a)(4); (b) 
        introductory text amended..................................26419
1201.304  (a) revised..............................................26420
1202.1  (f) and (g) revised; (i)(7) amended........................26420
1203.405  Redesignated from 1203.409...............................26420
1203.409  Redesignated as 1203.405.................................26420
1211.104--1211.104-70 (Subpart 1211.1)  Added......................26420
1211.204-70 (Subpart 1211.2)  Added................................26420
1214.303  (b) amended..............................................26420
1237.104--1237.104-90 (Subpart 1237.1)  Added......................26420
1246.701-70  Amended...............................................26420
1252.219-70  (b) removed; (c) redesignated as (b)..................26420
1253.303 (Subpart 1253.3)  Appendix amended........................26421
Chapter 14
1401.106 (Subpart 1401.1)  Revised.................................18054
1401.303 (Subpart 1401.3)  Revised.................................18054
1401.601--1401.670-4 (Subpart 1401.6)  Removed.....................18054